# EDGAR Filing Document

**Accession Number:** 0001124198
**File Stem:** 0001124198-26-000007
**Filing Date:** 2026-2
**Character Count:** 400148
**Document Hash:** 7f9210bc8d5d4a5c9dc321f28eacc27b
**Contains OCR:** False
**Source Format:** 

## Filing Content

## Filing Summary
**0001124198-26-000007.hdr.sgml**: 20260217

**ACCESSION NUMBER**: 0001124198-26-000007

**CONFORMED SUBMISSION TYPE**: 10-K

**PUBLIC DOCUMENT COUNT**: 107

**CONFORMED PERIOD OF REPORT**: 20251231

**FILED AS OF DATE**: 20260217

**DATE AS OF CHANGE**: 20260217

**FILER**: 

**COMPANY DATA:**
- **COMPANY CONFORMED NAME:** FLUOR CORP
- **CENTRAL INDEX KEY:** 0001124198
- **STANDARD INDUSTRIAL CLASSIFICATION:** HEAVY CONSTRUCTION OTHER THAN BUILDING CONST - CONTRACTORS [1600]
- **ORGANIZATION NAME:** 05 Real Estate & Construction
- **EIN:** 330927079
- **STATE OF INCORPORATION:** DE
- **FISCAL YEAR END:** 1231

**FILING VALUES:**
- **FORM TYPE:** 10-K
- **SEC ACT:** 1934 Act
- **SEC FILE NUMBER:** 001-16129
- **FILM NUMBER:** 26636341

**BUSINESS ADDRESS:**
- **STREET 1:** 6700 LAS COLINAS BLVD
- **CITY:** IRVING
- **STATE:** TX
- **ZIP:** 75039
- **BUSINESS PHONE:** 4693987000

**MAIL ADDRESS:**
- **STREET 1:** 6700 LAS COLINAS BLVD
- **CITY:** IRVING
- **STATE:** TX
- **ZIP:** 75039

?xml version='1.0' encoding='ASCII'? flr-20251231

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

<u>[FLUOR CORPORATION INDEX TO CONSOLIDATED FINANCIAL STATEMENTS](#i99155b137c484eadafc407f6a8cc1413_106)</u>

**UNITED STATES**

**SECURITIES AND EXCHANGE COMMISSION**

**Washington, D.C. 20549**

**Form 10-K** 

☒ **ANNUAL REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934**

**For the fiscal year ended December 31, 2025** 

**or**

☐ **TRANSITION REPORT PURSUANT TO SECTION 13 OR 15(d) OF THE SECURITIES EXCHANGE ACT OF 1934**

**For the transition period from&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp; &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;to &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;**

---

| | |
|:---|:---|
| **Commission file number:** | **1-16129** |

---

**FLUOR CORPORATION** 

*(Exact name of registrant as specified in its charter)*

---

| | | |
|:---|:---|:---|
| **Delaware** | **Delaware** | **33-0927079** |
| *(State or other jurisdiction of* | *(State or other jurisdiction of* | *(I.R.S. Employer* |
| *incorporation or organization)* | *incorporation or organization)* | *Identification No.)* |
| **6700 Las Colinas Boulevard** | **6700 Las Colinas Boulevard** | |
| **Irving,** | **Texas** | **75039** |
| *(Address of principal executive offices)* | *(Address of principal executive offices)* | *(Zip Code)* |

---

**469-398-7000** 

*(Registrant's telephone number, including area code)*

**Securities registered pursuant to Section 12(b) of the Act:**

---

| | | |
|:---|:---|:---|
| **Title of Each Class** | **Trading Symbol(s)** | **Name of Each Exchange on Which Registered** |
| Common Stock, $.01 par value per share | FLR | New York Stock Exchange |

---

**Securities registered pursuant to Section 12(g) of the Act:**

**None**

Indicate by check mark if the registrant is a well-known seasoned issuer, as defined in Rule 405 of the Securities Act. Yes 🗹&nbsp;&nbsp;&nbsp;&nbsp;No □

Indicate by check mark if the registrant is not required to file reports pursuant to Section 13 or Section 15(d) of the Exchange Act. Yes □ No 🗹

Indicate by check mark whether the registrant (1) has filed all reports required to be filed by Section 13 or 15(d) of the Exchange Act during the preceding 12 months (or for such shorter period that the registrant was required to file such reports), and (2) has been subject to such filing requirements for the past 90 days. Yes 🗹&nbsp;&nbsp;&nbsp;&nbsp;No □

Indicate by check mark whether the registrant has submitted electronically every Interactive Data File required to be submitted pursuant to Rule 405 of Regulation S-T (§232.405 of this chapter) during the preceding 12 months (or for such shorter period that the registrant was required to submit such files). Yes 🗹&nbsp;&nbsp;&nbsp;&nbsp;No □

Indicate by check mark whether the registrant is a large accelerated filer, an accelerated filer, a non-accelerated filer, a smaller reporting company or an emerging growth company. See the definitions of "large accelerated filer," "accelerated filer," "smaller reporting company" and "emerging growth company" in Rule 12b-2 of the Exchange Act.

Large accelerated filer 🗹 Accelerated filer □ Non-accelerated filer □ Smaller reporting company ☐ Emerging growth company ☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. □

Indicate by check mark whether the registrant has filed a report on and attestation to its management's assessment of the effectiveness of its internal control over financial reporting under Section 404(b) of the Sarbanes-Oxley Act (15 U.S.C. 7262(b)) by the registered public accounting firm that prepared or issued its audit report. ☑

If securities are registered pursuant to Section 12(b) of the Act, indicate by check mark whether the financial statements of the registrant included in the filing reflect the correction of an error to previously issued financial statements. □

Indicate by check mark whether any of those error corrections are restatements that required a recovery analysis of incentive-based compensation received by any of the registrant's executive officers during the relevant recovery period pursuant to §240.10D-1(b). □

Indicate by check mark whether the registrant is a shell company (as defined in Rule 12b-2 of the Exchange Act). Yes ☐&nbsp;&nbsp;&nbsp;&nbsp;No ☑

As of June 30, 2025, the aggregate market value of the registrant's common stock held by non-affiliates of the registrant was approximately $8.2 billion based on the closing sale price as reported on the New York Stock Exchange.

As of January 31, 2026, 146,564,673 shares of the registrant's common stock, $0.01 par value per share, were outstanding.

---

| |
|:---|
| **DOCUMENTS INCORPORATED BY REFERENCE** |
| Portions of the Proxy Statement for the 2026 Annual Meeting of Stockholders are incorporated by reference into Part III of this Form 10-K. |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**INDEX TO ANNUAL REPORT ON FORM 10-K**

**For the Fiscal Year Ended December 31, 2025**

---

| | | |
|:---|:---|:---|
| | | **Page** |
| | <u>[Glossary of Terms](#i99155b137c484eadafc407f6a8cc1413_10)</u> | <u>[1](#i99155b137c484eadafc407f6a8cc1413_10)</u> |
| | <u>[Forward-Looking Information](#i99155b137c484eadafc407f6a8cc1413_13)</u> | <u>[2](#i99155b137c484eadafc407f6a8cc1413_13)</u> |
| | **<u>[PART I](#i99155b137c484eadafc407f6a8cc1413_16)</u>** | |
| <u>[Item 1.](#i99155b137c484eadafc407f6a8cc1413_19)</u> | <u>[Business](#i99155b137c484eadafc407f6a8cc1413_19)</u> | <u>[3](#i99155b137c484eadafc407f6a8cc1413_19)</u> |
| <u>[Item 1A.](#i99155b137c484eadafc407f6a8cc1413_22)</u> | <u>[Risk Factors](#i99155b137c484eadafc407f6a8cc1413_22)</u> | <u>[12](#i99155b137c484eadafc407f6a8cc1413_22)</u> |
| <u>[Item 1B.](#i99155b137c484eadafc407f6a8cc1413_25)</u> | <u>[Unresolved Staff Comments](#i99155b137c484eadafc407f6a8cc1413_25)</u> | <u>[27](#i99155b137c484eadafc407f6a8cc1413_25)</u> |
| <u>[Item 1C](#i99155b137c484eadafc407f6a8cc1413_28)</u>. | <u>[Cybersecurity](#i99155b137c484eadafc407f6a8cc1413_28)</u> | <u>[27](#i99155b137c484eadafc407f6a8cc1413_28)</u> |
| <u>[Item 2.](#i99155b137c484eadafc407f6a8cc1413_31)</u> | <u>[Properties](#i99155b137c484eadafc407f6a8cc1413_31)</u> | <u>[29](#i99155b137c484eadafc407f6a8cc1413_31)</u> |
| <u>[Item 3.](#i99155b137c484eadafc407f6a8cc1413_34)</u> | <u>[Legal Proceedings](#i99155b137c484eadafc407f6a8cc1413_34)</u> | <u>[29](#i99155b137c484eadafc407f6a8cc1413_34)</u> |
| <u>[Item 4.](#i99155b137c484eadafc407f6a8cc1413_37)</u> | <u>[Mine Safety Disclosures](#i99155b137c484eadafc407f6a8cc1413_37)</u> | <u>[29](#i99155b137c484eadafc407f6a8cc1413_37)</u> |
|  | **<u>[PART II](#i99155b137c484eadafc407f6a8cc1413_40)</u>** |  |
| <u>[Item 5.](#i99155b137c484eadafc407f6a8cc1413_43)</u> | <u>[Market for Registrant's Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities](#i99155b137c484eadafc407f6a8cc1413_43)</u> | <u>[30](#i99155b137c484eadafc407f6a8cc1413_43)</u> |
| <u>[Item 6.](#i99155b137c484eadafc407f6a8cc1413_46)</u> | <u>[\[Reserved\]](#i99155b137c484eadafc407f6a8cc1413_46)</u> | <u>[31](#i99155b137c484eadafc407f6a8cc1413_46)</u> |
| <u>[Item 7.](#i99155b137c484eadafc407f6a8cc1413_49)</u> | <u>[Management's Discussion and Analysis of Financial Condition and Results of Operations](#i99155b137c484eadafc407f6a8cc1413_49)</u> | <u>[31](#i99155b137c484eadafc407f6a8cc1413_49)</u> |
| <u>[Item 7A.](#i99155b137c484eadafc407f6a8cc1413_55)</u> | <u>[Quantitative and Qualitative Disclosures About Market Risk](#i99155b137c484eadafc407f6a8cc1413_55)</u> | <u>[42](#i99155b137c484eadafc407f6a8cc1413_55)</u> |
| <u>[Item 8.](#i99155b137c484eadafc407f6a8cc1413_58)</u> | <u>[Financial Statements and Supplementary Data](#i99155b137c484eadafc407f6a8cc1413_58)</u> | <u>[43](#i99155b137c484eadafc407f6a8cc1413_58)</u> |
| <u>[Item 9.](#i99155b137c484eadafc407f6a8cc1413_61)</u> | <u>[Changes in and Disagreements with Accountants on Accounting and Financial Disclosure](#i99155b137c484eadafc407f6a8cc1413_61)</u> | <u>[43](#i99155b137c484eadafc407f6a8cc1413_61)</u> |
| <u>[Item 9A.](#i99155b137c484eadafc407f6a8cc1413_64)</u> | <u>[Controls and Procedures](#i99155b137c484eadafc407f6a8cc1413_64)</u> | <u>[43](#i99155b137c484eadafc407f6a8cc1413_64)</u> |
| <u>[Item 9B.](#i99155b137c484eadafc407f6a8cc1413_67)</u> | <u>[Other Information](#i99155b137c484eadafc407f6a8cc1413_67)</u> | <u>[45](#i99155b137c484eadafc407f6a8cc1413_67)</u> |
| <u>[Item 9C.](#i99155b137c484eadafc407f6a8cc1413_73)</u> | <u>[Disclosure Regarding Foreign Jurisdictions that Prevent Inspections](#i99155b137c484eadafc407f6a8cc1413_67)</u> | <u>[45](#i99155b137c484eadafc407f6a8cc1413_73)</u> |
|  | **<u>[PART III](#i99155b137c484eadafc407f6a8cc1413_76)</u>** |  |
| <u>[Item 10.](#i99155b137c484eadafc407f6a8cc1413_79)</u> | <u>[Directors, Executive Officers and Corporate Governance](#i99155b137c484eadafc407f6a8cc1413_79)</u> | <u>[46](#i99155b137c484eadafc407f6a8cc1413_79)</u> |
| <u>[Item 11.](#i99155b137c484eadafc407f6a8cc1413_82)</u> | <u>[Executive Compensation](#i99155b137c484eadafc407f6a8cc1413_82)</u> | <u>[46](#i99155b137c484eadafc407f6a8cc1413_82)</u> |
| <u>[Item 12.](#i99155b137c484eadafc407f6a8cc1413_85)</u> | <u>[Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters](#i99155b137c484eadafc407f6a8cc1413_85)</u> | <u>[46](#i99155b137c484eadafc407f6a8cc1413_85)</u> |
| <u>[Item 13.](#i99155b137c484eadafc407f6a8cc1413_88)</u> | <u>[Certain Relationships and Related Transactions, and Director Independence](#i99155b137c484eadafc407f6a8cc1413_88)</u> | <u>[47](#i99155b137c484eadafc407f6a8cc1413_88)</u> |
| <u>[Item 14.](#i99155b137c484eadafc407f6a8cc1413_91)</u> | <u>[Principal Accountant Fees and Services](#i99155b137c484eadafc407f6a8cc1413_91)</u> | <u>[47](#i99155b137c484eadafc407f6a8cc1413_91)</u> |
|  | **<u>[PART IV](#i99155b137c484eadafc407f6a8cc1413_94)</u>** |  |
| <u>[Item 15.](#i99155b137c484eadafc407f6a8cc1413_97)</u> | <u>[Exhibits and Financial Statement Schedules](#i99155b137c484eadafc407f6a8cc1413_97)</u> | <u>[48](#i99155b137c484eadafc407f6a8cc1413_97)</u> |
| <u>[Item 16.](#i99155b137c484eadafc407f6a8cc1413_100)</u> | <u>[Form 10-K Summary](#i99155b137c484eadafc407f6a8cc1413_100)</u> | <u>[51](#i99155b137c484eadafc407f6a8cc1413_100)</u> |
| <u>[Signatures](#i99155b137c484eadafc407f6a8cc1413_103)</u> | <u>[Signatures](#i99155b137c484eadafc407f6a8cc1413_103)</u> | <u>[51](#i99155b137c484eadafc407f6a8cc1413_103)</u> |

---

i

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Glossary of Terms**

The abbreviations and definitions set forth below apply to the Fluor-specific terms used throughout this filing.

---

| | |
|:---|:---|
| **Abbreviation/Term** | **Definition** |
| AMECO | American Equipment Company, Inc. |
| Fluor | Fluor Corporation |
| NuScale | NuScale Power Corporation |
| SGI | Stock growth incentive awards |
| Stork | Stork Holding B.V. and subsidiaries |

---

The abbreviations and definitions set forth below apply to the indicated terms used throughout this filing.

---

| | |
|:---|:---|
| **Abbreviation/Term** | **Definition** |
| 2025 10-K | Annual Report on Form 10-K for the year ended December 31, 2025 |
| AOCI | Accumulated other comprehensive income (loss) |
| APIC | Additional paid-in capital |
| ASC | Accounting Standards Codification |
| ASU | Accounting Standards Update |
| CFM | Customer-furnished materials |
| CODM | Chief operating decision maker |
| CPS | Convertible preferred stock |
| CTA | Currency translation adjustment |
| DB plan | Defined benefit pension plan |
| DC plan | Defined contribution pension plan |
| DOD | U.S. Department of Defense (also known as Department of War) |
| DOE | U.S. Department of Energy |
| DOJ | U.S. Department of Justice |
| EPC | Engineering, procurement and construction |
| EPS | Earnings per share |
| Exchange Act | Securities Exchange Act of 1934 |
| FASB | Financial Accounting Standards Board |
| FEMA | U.S. Federal Emergency Management Agency |
| FTC | Foreign tax credit |
| G&A | General and administrative expense |
| GAAP | Accounting principles generally accepted in the United States |
| GILTI | Global Intangible Low-Taxed Income |
| ICFR | Internal control over financial reporting |
| IP | Intellectual property |
| IT | Information technology |
| LNG | Liquefied natural gas |
| NCI | Noncontrolling interests |
| NM | Not meaningful |
| NOL | Net operating loss |
| NRC | U.S. Nuclear Regulatory Commission |
| OBBB | One Big Beautiful Bill, signed into U.S. law in July 2025 |
| OCI | Other comprehensive income (loss) |
| PBO | Projected benefit obligation |
| PIPE | Private investment in public equity |
| PP&E | Property, plant and equipment |
| RSU | Restricted stock units |
| RUPO | Remaining unsatisfied performance obligations |
| SEC | Securities and Exchange Commission |
| SPAC | Special purpose acquisition company |
| TSR | Total shareholder return |
| VIE | Variable interest entity |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Forward-Looking Information**

From time to time, we make certain comments and disclosures in reports and statements, including this 2025 10-K, or statements are made by our officers or directors, that, while based on reasonable assumptions, may be forward-looking in nature. Under the Private Securities Litigation Reform Act of 1995, a "safe harbor" may be provided to us for certain of these forward-looking statements. We caution readers that forward-looking statements, including disclosures which use words such as "will," "may," "could," "should," "believes," "anticipates," "plans," "expects," "intends," "estimates," "projects," "potential," "goals," "target," "continue" and similar statements are subject to various future risks and uncertainties which could cause actual results of operations to differ materially from expectations.

Any forward-looking statements that we may make are based on our current expectations and beliefs concerning future developments and their potential effects on us. There can be no assurance that future developments affecting us will be those anticipated by us. Any forward-looking statements are subject to the risks, uncertainties and other factors that could cause actual results of operations, financial condition, cost reductions, acquisitions, dispositions, financing transactions, operations and other events to differ materially from those expressed or implied in such forward-looking statements.

We are subject to known risks and to potentially unknown risks. While most risks affect only future cost or revenue anticipated by us, some risks may relate to accruals that have already been reflected in earnings. Our failure to receive payments of expected amounts or the incurrence of liabilities in excess of amounts recorded, could result in charges against future earnings. As a result, we caution readers to recognize and consider the inherently uncertain nature of forward-looking statements and not to place undue reliance on them.

These factors include those referenced or described in this 2025 10-K (including in "Item 1A. — Risk Factors"). We cannot control all risks and uncertainties, and in many cases, we cannot predict the risks and uncertainties that could cause our actual results to differ materially from those indicated by the forward-looking statements. You should consider these risks and uncertainties when you are evaluating us and deciding whether to invest in our securities. Except as otherwise required by law, we undertake no obligation to publicly update or revise our forward-looking statements, whether as a result of new information, future events or otherwise.

**Defined Terms**

Except as the context otherwise requires, the terms "Fluor" or the "Registrant" as used herein are references to Fluor Corporation and its predecessors and references to the "company," "we," "us," or "our" as used herein shall include Fluor Corporation, its consolidated subsidiaries and joint ventures.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**PART I**

**Item 1.&nbsp;&nbsp;&nbsp;&nbsp;*Business***

Fluor is dedicated to **<u>building a better world</u>** by applying our world-class expertise to solve our clients' greatest challenges. We deliver professional and technical solutions that emphasize safety, operational excellence and capital efficiency for our clients. Incorporated in Delaware in September 2000, Fluor and its predecessors have served clients for over 110 years, consistently supporting development and progress. We believe we are poised to continue helping our clients meet similar needs into the foreseeable future.

Through our subsidiaries and joint ventures, we stand among the world's leading professional services firms, offering EPC and project management services. We provide these services to our clients in diverse industries worldwide including life sciences, advanced technologies and manufacturing, data centers, mining and metals, gas and nuclear derived power, infrastructure, chemicals, LNG, and oil and gas production and fuels. We are also a service provider to the U.S. federal government and governments abroad.

Our operations are organized into 3 principal segments: Urban Solutions, Energy Solutions and Mission Solutions. Additional activities are reported under our Other segment.

**Strategic Priorities**

We are guided by 4 strategic priorities for driving value creation for our shareholders:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• **Drive growth across our portfolio** by growing our market positions in energy addition, low carbon power, LNG, sustainable chemicals, data centers, semiconductors, critical metals and minerals and national security while maintaining our industry leading position in traditional oil & gas, chemicals, commodity mining, life sciences and supporting the DOE.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• **Pursue contracts with fair and balanced commercial terms** by focusing on pursuing contracts with more favorable, risk-adjusted terms that reward us for value, enhancing our business acumen, focusing on reimbursable terms and only considering fixed-price contracts for segments and scopes where we have a strong position and strategy for delivering expected returns.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• **Reinforce financial discipline** by strengthening our financial position through predictable cash flow and earnings. Our capital allocation priorities include investing in our people and growth markets, maintaining low debt leverage and returning capital to shareholders.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• **Foster a high-performance culture of project delivery** by using A.I. and technology to improve cost and schedule, to support quality project execution and delivering results for our clients.

In 2025, we continued to make progress on our strategic priorities. As of December 31, 2025, 81% of our backlog is reimbursable.

**Our Core Values**

Our Core Values serve as our behavioral compass, guiding all of our actions. They are not only what we believe, they are the foundation of how we achieve our purpose to build a better world.

---

| | | | |
|:---|:---|:---|:---|
| **SAFETY** | **INTEGRITY** | **TEAMWORK** | **EXCELLENCE** |
| **We care for each other** | **We do what is right** | **We work better together** | **We deliver solutions** |
| Safer Together<sup>SM</sup> promotes the well-being of all people, our communities and the environment. | Trust, accountability and fairness define our character. | Collectively we thrive when we include, respect and empower one another. | Our high-performance teams embrace opportunities, solve challenges and continuously improve. |

---

**Competitive Strengths**

As a world-class provider of technical and professional services, we believe that we bring capital efficient business solutions to our clients. We believe that our business advantages and global positioning provide us with significant competitive strengths, including:

*Safety.* Maintaining a **<u>safe and secure workplace</u>** is a key business driver for us and our clients. In our experience, whether in an office or at a jobsite, our commitment to safety reduces risks, supports the well-being of our workforce,

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

enhances morale, improves productivity, reduces project costs and strengthens client relationships. Our safety culture is a defining feature of our organization.

*Global Execution Platform.* As a leading publicly traded EPC firm, our **<u>global footprint</u>** enables us to build local relationships, seize opportunities and rapidly mobilize resources to project sites worldwide. We regularly form strategic alliances with local partners, utilize our supply chain expertise and emphasize local training programs. Our distributed execution centers deliver high quality services on a cost-efficient basis.

*Excellence in Execution.* We believe that our ability to **<u>execute, maintain and manage complex projects</u>**, large or small and often in geographically challenging locations, gives us a distinct competitive advantage. We strive to complete our projects meeting or exceeding all client specifications. We continue to improve our approach to data-driven execution and the use of A.I. and other technologies, which has enhanced our ability to meet our clients' needs.

*Market Diversity.* We offer services across a **<u>wide range of industries</u>** globally. This diversification helps mitigate the impact of market cyclicality and enables us to strive for more consistent growth. We believe that maintaining a balanced business portfolio allows us to focus on our more stable markets while capitalizing on cyclical or emerging markets when the timing is appropriate.

*Client Relationships.* We actively cultivate new relationships while also building on our long-term relationships with existing clients. We believe that long-term relationships with existing clients serve us well by allowing us to better understand and **<u>be more responsive</u>** to their requirements. Whether our clients are new or have been with us for many decades, our ability to successfully foster and maintain relationships remains a key strength.

*Risk Management.* We believe we have the ability to assess, mitigate and manage project risk, particularly in challenging locations or circumstances. Our experienced management and execution team employs a **<u>systematic and disciplined approach</u>** to identifying, assessing and managing risks. We believe that this risk management approach helps us control costs and adhere to clients' schedules.

*Sustainability.* Our sustainability charter is to conduct business with social, economic and environmental responsibility. Sustainability is integrated into our business practices, and our employees are engaged in delivery on our charter, enabling us to **<u>build and sustain the global community</u>** and provide value for our stakeholders.

**General Operations**

Our services span 6 broad categories, from consulting activities to complete design-build, operations and maintenance contracts.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• In <u>engineering and design</u>, we develop solutions to address our clients' most complex challenges. Our engineering services encompass traditional engineering disciplines such as piping, mechanical, electrical, control systems, civil, structural and architectural, as well as advanced engineering specialties including process engineering, chemical engineering, simulation, integrated automation processes and interactive 3-D modeling. Through our design solutions, we offer a range of services including front-end engineering, conceptual design, estimating, feasibility studies, permitting, process simulation, technology and licensing evaluation, scope definition and siting.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• <u>Project management</u> involves managing all aspects of the effort to deliver projects on schedule and within budget, and is critical on every project. We are often hired as the overall program manager for large, complex projects involving multiple contractors and subcontractors, requiring the integration of various activities into a cohesive execution plan. Our project management services include logistics, development of project execution plans, detailed schedules, cost forecasts, progress tracking and reporting, and the integration of EPC efforts. This approach helps us meet our clients' safety, functionality and financial performance requirements.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our <u>procurement</u> offerings provide supply chain solutions aimed at improving product quality and performance while reducing project costs and schedules. Clients benefit from our global sourcing and supply expertise, purchasing power, technical knowledge, processes, systems and experienced global resources. Our procurement activities include strategic sourcing, material management, contracts management, buying, expediting, supplier quality inspection and logistics.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• In <u>construction</u>, we mobilize, execute and commission projects on a self-perform and/or subcontracted basis. We are generally responsible for project completion, often in difficult locations and under challenging circumstances. We are frequently designated as program manager, and serve as such in cases where the client has facilities in multiple locations, complex phases in a single project location, or a large-scale investment in one facility.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We offer <u>operations and maintenance</u> services designed to enhance the efficiency or extend the life of our clients' facilities. These services may include facility management, technical facility operations, plant readiness, commissioning, start-up and maintenance technology, small capital projects, turnaround and outage services and recapitalization of facilities and infrastructure. Additionally, we can provide key management, staffing and management skills to clients on-site at their facilities.

**<u>Business Segments</u>**

**Urban Solutions**

We believe that ongoing urbanization is driving demand for innovative and sustainable solutions in advanced technologies and manufacturing, life sciences, mining and metals, infrastructure and professional staffing project teams. Urban Solutions includes businesses to meet our clients' needs in these evolving and growing markets.

For advanced technologies and manufacturing, we deliver front-end engineering, program management and EPC services to a diverse range of companies globally. Our expertise spans a wide variety of market segments, including advanced materials, data centers, semiconductors, smart batteries, fast-moving consumer goods, food and beverage and specialty products. We specialize in designing projects that incorporate lean manufacturing principles, helping clients accelerate their time to market.

In life sciences, we offer front-end studies and EPC services to the pharmaceutical, biotechnology, medical device and animal health industries. We also specialize in providing validation and commissioning services, bringing new facilities online and extending the life or improving the capabilities of existing facilities. We believe our ability to complete large-scale projects, especially where time to market is critical, enables us to better serve our clients and is a key competitive advantage.

In mining and metals, we provide a comprehensive range of services to clients producing various commodities, including copper, lithium, rare earth minerals, iron ore, bauxite, alumina, aluminum, steel, diamond, gold and fertilizers. Our services include conceptual and feasibility studies through detailed EPC, commissioning and startup support. Many of our opportunities are located in remote or logistically challenging regions, and our scale, regional presence and experience enable us to execute large scale mining and metals projects worldwide.

In infrastructure, we support the development of projects with a focus on state departments of transportation. We provide a broad range of services, including consulting, design, planning, financial structuring, engineering, construction and operation and maintenance services. Continuing urbanization and the replacement and expansion of aging infrastructure in North America continues to drive project opportunities.

The segment's staffing services are often provided through TRS Staffing Solutions®, a global staffing specialist that supplies us and third-party clients with technical, professional and craft resources either on a contract or more permanent placement basis.

In North America, Plant & Facility Services provides clients with a comprehensive suite of outsourced and consultative reliability and maintenance services, focusing on power generation and the industrial manufacturing sector.

**Energy Solutions**

Our Energy Solutions segment offers EPC services for traditional oil and gas markets, including upstream, fuels, chemicals, LNG and power markets. We serve clients in these industries with comprehensive project life-cycle services, including expansion and modernization projects as well as in sustaining capital work. Our extensive skill set also supports energy transition markets, including nuclear power and other low-carbon energy sources, asset decarbonization, carbon capture, renewable fuels, green chemicals and hydrogen.

We excel at delivering large, complex projects in challenging locations, and as energy and chemicals work becomes more globally and geopolitically complex, clients rely on our expertise and proven global capabilities.

Our role is tailored to each project's requirements. We may provide front-end engineering, program management and final design services; construction management and self-perform construction; or oversight of other contractors. We also manage procurement of materials, equipment and subcontractors. Our capabilities include designing and constructing new facilities, as well as upgrading, optimizing, modernizing and expanding existing ones. Additionally, we offer consulting services ranging from feasibility studies and process assessments to project finance structuring.

In production and fuels, we deliver projects across the oil and gas value chain, including production, processing, refining and energy transition initiatives. Our upstream work covers field development, pipelines, offshore facilities and gas

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

processing. Downstream, we help clients upgrade refineries for greater capacity, efficiency and sustainability, and we repurpose facilities for renewable fuels and low carbon solutions.

We have been very active for several decades in the chemicals and petrochemicals market, with major projects in the ethylene-based markets and various specialty chemicals. We are also involved in battery chemicals projects and implementing lower carbon solutions on existing and new chemical facilities.

In LNG, we have participated in a wide range of developments, including liquefaction, floating LNG facilities, mid-scale LNG solutions and regasification terminals. Our work in LNG includes feasibility studies, technology evaluations, process equipment optimization and selection, basic design, front-end engineering and design, detailed EPC and start-up assistance.

In the power market, we can provide a full range of services utilizing small modular and conventional nuclear reactor technologies, as well as solutions utilizing thermal power sources. We have extensive experience in gas-fired power plants.

**Mission Solutions**

Mission Solutions delivers advanced technical services to the U.S. and other governments. We believe the segment's nuclear and environmental business holds a tier 1 position with differentiated expertise in managing complex national security missions across the DOE and the National Nuclear Security Administration. We deliver solutions for nuclear security and operations, fuels enrichment, nuclear waste management and laboratory management. As an industry leader in nuclear remediation, we oversee site management, environmental remediation and decommissioning at government facilities, effectively addressing environmental and regulatory challenges. In civil services, we are a partner to FEMA for disaster recovery and emergency response.

In our national security business, we deliver operations and maintenance, global logistics, EPC, life support and operations of mission-critical facilities across U.S. military service organizations. We can rapidly mobilize people and equipment to deliver solutions globally, often in harsh environments. We are capable of delivering solutions to our military clients irrespective of the location or the speed required. We also offer a bench of security-cleared personnel providing critical solutions to clients in the intelligence community, including data center management, operations and maintenance of secure facilities and technology platform services. We construct and renovate secure facilities around the world for various agencies in support of their enduring missions.

**Other**

Other previously included the results of NuScale prior to its deconsolidation in October 2024, and the remaining operations of Stork which was fully divested in 2025. Results from our Other segment were immaterial for 2025.

Prior to November 2025, we converted 15 million of our 126 million NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares and sold all 15 million of those shares for net proceeds of $605 million. We converted the remaining 111 million of our NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares upon reaching agreement with NuScale in November 2025. In November 2025, through an indirect, wholly-owned subsidiary, we entered into a variable price forward sale agreement whereby we pledged and granted a security interest in 71 million of our remaining shares in NuScale, while maintaining continuing involvement and ownership rights, and committed to sell, convey, transfer, assign and deliver those shares at the final settlement date in the first quarter of 2026. Through our bank's execution, we completed the sale of all 71 million shares of NuScale on February 13, 2026, generating total proceeds of $1.35 billion. We expect to monetize the remaining 40 million shares of NuScale via similar structured programs and expect that all remaining ownership in NuScale should be sold by the second quarter of 2026.

**Other Matters**

*Types of Contracts*

While the basic terms and conditions of the contracts that we perform may vary considerably, we typically perform our work under two broad types of contracts: (a) reimbursable contracts and (b) lump-sum or guaranteed maximum contracts. In some limited markets, we are seeing hybrid contracts containing both lump-sum and reimbursable elements. For our material hybrid contracts, we split the contract and report backlog based on both the lump-sum and reimbursable elements. As of December 31, 2025, the following table summarizes contract type within our ending backlog:

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

---

| | | | | |
|:---|:---|:---|:---|:---|
| | **December 31,** | **December 31,** | **December 31,** | **December 31,** |
|<br>**(in millions)** | **2025** | **2025** | **2024** | **2024** |
| Reimbursable | $20713 | 81% | $22589 | 79% |
| Lump-Sum and Guaranteed Maximum | 4823 | 19% | 5895 | 21% |

---

Under reimbursable contracts, the client reimburses us based upon negotiated rates and fees. Our profit may be in the form of a fee, a simple markup applied to labor cost incurred in performing the contract, or a combination of the two. The fee element may also vary. The fee may be an incentive fee based upon achieving certain performance factors, milestones or targets; it may be a fixed amount in the contract; or it may be based upon a percentage of the cost incurred. In some cases, reimbursable contracts may be converted into lump-sum contracts. Reimbursable contracts may include significant estimated amounts of CFM.

Mission Solutions, primarily acting as a prime contractor or a major subcontractor for a number of government programs, generally performs its services under reimbursable contracts subject to applicable statutes and regulations. In many cases, these contracts include incentive fee arrangements. The programs may span many years and may be implemented by awards under multiple contracts. Some of our government contracts are known as indefinite delivery indefinite quantity ("IDIQ") agreements. Under these arrangements, we work closely with the government to define the scope and amount of work required based upon an estimate of the maximum amount that the government desires to spend. While the scope is often not initially fully defined or does not require any specific amount of work, once the project scope is determined, additional work may be awarded to us without the need for further competitive bidding.

Under lump-sum contracts, we may bid based upon preliminary engineering drawings and specifications provided by the client. This type of contracting presents risk because, among other things, it requires us to predetermine the work to be performed, the project execution schedule and all costs associated with the work based on incomplete information, all of which requires us to make pricing assumptions based on judgment informed by prior experience on other projects. This risk may be greater when we provide a lump-sum bid in competition with other contractors because we may not be selected for the work if our bid is higher than the competition. Another type of lump-sum contract is a negotiated fixed-price contract, under which we are selected as contractor first and then negotiate a lump-sum price with the client. This may reduce the risk associated with bidding in competition. Furthermore, negotiated fixed-price contracts may occur under a compensation model in which we perform some of the early work on a project, including to advance the engineering, on a reimbursable basis before agreeing upon and converting to a lump-sum price for the remainder of the project. Depending upon when a project converts from reimbursable to lump-sum, our risk may lessen because we may hold greater insight into the details of the project scope, engineering and schedule thereby reducing the number and character of the pricing assumptions in the agreed-upon lump-sum price. Another type of lump-sum contract is a unit price contract under which we are paid a set amount for every "unit" of work performed. If we perform well under any type of lump-sum contract, we can benefit from cost savings gained from the effects of our efficiencies. However, if the project does not proceed as originally planned, we strive to develop timely change orders, but we may not be able to recover cost overruns, which may cause us to lose money.

Guaranteed maximum price contracts are reimbursable contracts except that the total fee plus the total cost cannot exceed an agreed upon guaranteed maximum price. We can be responsible for some or all of the total cost of the project if the cost exceeds the guaranteed maximum price. Where the total cost is less than the negotiated guaranteed maximum price, we may receive the benefit of the cost savings based upon the terms of the contract.

Some of our contracts, regardless of type, may operate under joint ventures or other teaming arrangements. Typically, we prefer to enter into these arrangements with companies with whom we have worked previously. These arrangements are generally made to strengthen our market position or technical skills, or where the size, scale or location of the project directs the use of such arrangements.

*Competition*

The markets served by our business are highly competitive and, for the most part, require substantial resources and highly skilled and experienced technical personnel. A large number of companies compete against us, including U.S.-based companies such as AECOM, Amentum Services, Inc., Bechtel Group, Inc., Black & Veatch, Burns & McDonnell, BWXT Technologies, Inc., EMCOR Group, Inc., Jacobs Solutions, Inc., KBR, Inc., Kiewit Corporation, Parsons Corporation, Turner Construction Company, V2X, Inc. and Zachry Group, and international-based companies such as ACS Actividades de Construccion y Servicios, Balfour Beatty plc, Chiyoda Corporation, Exyte GmbH, Hatch Ltd., JGC Corporation, Petrofac Limited, AtkinsRéalis, Technip Energies N.V., Wood Group plc, and WorleyParsons Limited.

Competition for our Energy Solutions and Urban Solutions segments is based on an ability to provide the design, engineering, planning, management and project execution skills required to complete complex projects in a safe, timely and

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

cost-efficient manner. We believe our engineering, procurement and construction business derives its competitive strength from our market diversity, excellence in execution, reputation for quality, technology, cost-effectiveness, worldwide procurement capability, project management expertise, geographic coverage, ability to meet client requirements by performing construction on either a union or an open shop basis, ability to execute complex projects of varying sizes, strong safety record and lengthy experience with a wide range of services and technologies.

The temporary staffing business is a highly fragmented market with over 1,000 companies competing globally. The key competitive factors in this business line are price, service, quality, client relationships, breadth of service and the ability to identify and retain qualified personnel and geographic coverage.

In our Mission Solutions segment, key competitive factors are primarily centered on performance, qualified personnel with appropriate clearance credentials and the ability to provide the design, engineering, planning, management and project execution skills required to complete complex projects in a safe, timely, cost-efficient and compliant manner.

*Significant Clients*

For 2025, revenue earned from agencies of the U.S. government accounted for 17% of our total revenue. We perform work for these government agencies under multiple contracts and sometimes through joint venture arrangements. Additionally, revenue from a single Urban Solutions' customer spanning multiple projects amounted to 15% of our revenue in 2025.

*Raw Materials*

The principal products we use in our business include structural steel, metal plate, concrete, cable and various electrical and mechanical components. These products and components are subject to raw material (aluminum, copper, nickel, iron ore, etc.) availability and pricing fluctuations, which we monitor on a regular basis. We have access to numerous global supply sources; however, the availability and cost of these products, components and raw materials may vary significantly from year to year due to various factors including the logistics market, client demand, producer capacity, inflation, market conditions and specific material shortages. Our pursuit of balanced contractual risk and implementation of various risk mitigation strategies often permits us to minimize such market-driven impacts on our contracts.

*Intellectual Property*

We have developed, acquired or otherwise have the right to license technology, know-how, and other proprietary rights that we maintain and protect using a variety of IP protections including patents, trade secrets, and contractual terms in commercial agreements, including confidentiality and license agreements. The various forms of protection are relied upon to support our technology offerings, such as our carbon capture and sulfur recovery service offerings.

*Seasonality*

Our operations can be subject to seasonal and other variations. These variations are influenced by, among other things, weather, customer spending patterns, bidding seasons, receipt of required regulatory approvals, project timing and schedules, and holidays. For example, harsher weather conditions in winter may impact our ability to complete work in parts of North America and the holiday season schedule affects our productivity during this period. For these reasons, coupled with the number and significance of client contracts commenced and completed during a particular period, as well as the timing of expenses incurred for corporate initiatives, it is not unusual for us to experience seasonal changes or fluctuations in our quarterly operating results.

**Compliance with Government Regulations**

*Environmental* 

We operate at sites around the world, including locations that involve activities related to nuclear facilities, hazardous waste, hydrocarbon production, distribution and transport, the military, and infrastructure. Some of our work takes place near environmentally sensitive areas such as wetlands, lakes and rivers.

We contract with governments to remediate hazardous materials, including chemical agents, as well as to decontaminate and decommission nuclear sites. These activities can require us to manage, handle, remove, treat, transport and dispose of toxic, radioactive or hazardous substances, and are subject to many environmental, health and safety laws and regulations.

We believe that we are compliant with environmental, health and safety requirements. We further believe that any reserves associated with future environmental costs are adequate and that any future costs will not have a material effect on our financial position or future results of operations. Some factors, however, could result in the recognition of additional

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

expense. These include the imposition of more stringent requirements under environmental laws or regulations, new developments or changes regarding site cleanup costs or the allocation of such costs among potentially responsible parties, or a determination that we are potentially responsible for the release of hazardous substances at sites other than those currently identified.

*Government Procurement*

The services we provide to the U.S. federal government are subject to Federal Acquisition Regulation, the Truth in Negotiations Act, Cost Accounting Standards, the Services Contract Act, False Claims Act, export controls rules and Department of Defense security regulations, as well as many other laws and regulations. These laws and regulations affect how we transact business with our clients and, in some instances, impose additional costs on our business operations. A violation of specific laws and regulations could lead to fines, contract termination or suspension of future contracts. Our government clients can also terminate, renegotiate, or modify any of their contracts with us at their convenience; and many of our government contracts are subject to renewal or extension annually.

*Anti-Bribery and Other Regulations*

We are subject to the U.S. Foreign Corrupt Practices Act, the U.K. Bribery Act of 2010, and similar anti-bribery laws, which generally prohibit companies and their intermediaries from making improper payments to foreign government officials for the purpose of obtaining or retaining business. To the extent we export technical services, data and products outside of the U.S., we are subject to U.S. and international laws and regulations governing international trade and exports, including, but not limited to, the International Traffic in Arms Regulations, the Export Administration Regulations, and trade sanctions against embargoed countries. We provide services to the Department of Defense and other defense-related entities that often require specialized professional qualifications and security clearances. In addition, as engineering design services professionals, we are subject to a variety of local, state, federal, and foreign licensing and permit requirements and ethics rules.

**Human Capital**

The following summarizes our human capital information as of December 31, 2025:

---

| | |
|:---|:---|
| | **Number of<br>Employees** |
| Salaried employees | 17122 |
| Craft and hourly employees | 4602 |
| TRS agency | 1271 |
| &nbsp;&nbsp;&nbsp;Total | 22995 |

---

The number of craft and hourly employees can vary in relation to the number, size and phase of execution of our projects. Total headcount reflects an 14% reduction from last year, primarily due to the sale of our Stork business in the U.K. as well as actions taken to enhance our operational efficiency.

We have employees in the following regions:

---

| | |
|:---|:---|
| **Region** | **% of Global Workforce** |
| North America | 58% |
| Europe, Africa and Middle East | 17% |
| Central and South America | 5% |
| Asia Pacific (includes Australia) | 20% |

---

*Health and Safety* 

Safety is one of our core values that guides everything we do. We are deeply committed to protecting our employees and preventing injuries across our offices and project sites. Through robust programs and procedures, we work diligently to mitigate the hazards inherent in our operations.

Our goal is to foster a caring, preventive culture built on proactive action by engaged employees. We call this commitment Safer Together<sup>SM</sup>. Beyond physical safety, we champion overall employee wellbeing. We provide resources such as mental health awareness campaigns, our global Employee Assistance Program, site-specific wellbeing programs and training in suicide prevention and mental health first aid.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

In 2025, our safety performance, calculated in accordance with U.S. Occupational Safety and Health Administration (OSHA) record keeping requirements, achieved a total case incident rate of 0.36, surpassing our goal of less than or equal to 0.38 and outperforming comparable industry benchmarks.

*Development Opportunities* 

One of our top priorities is to provide ongoing training and development for our employees through multiple avenues. We offer training for our executives, project execution and functional employees based in offices, remote locations and project field assignments. Additionally, employees can access Fluor University, our online platform, where they select from a wide variety of self-paced, online, virtual and instructor-led training courses. Topics range from our internally developed courses focused on discipline-specific training, to commercially available technical learning and general knowledge topics, such as leadership, business acumen and communication. In 2025, our employees received over 220,000 hours of training through Fluor University. We also offer comprehensive global initiatives targeted specifically for managers, including webinars on talent topics, monthly orientation training for new managers and a standardized resource toolkit for consistent talent development.

*Community Responsibility* 

As part of our culture, we offer our employees robust and enriching opportunities to help meet our goal of building a better world. In 2025, Fluor and our Fluor Foundation contributed $5 million to global charitable initiatives, improving communities where we live and operate. Through our employee giving and volunteering program, Fluor Cares, we empower our employees to invest in organizations and causes that resonate with them. This employee-driven giving and volunteering effort contributed an additional $5 million in 2025. Further, employees volunteered 47,000 hours to enrich the lives of their neighbors in need.

We have longstanding global programs and local efforts tailored to the needs of the communities where we operate. Through our charitable partners and the volunteerism of our employees, we delivered 594,000 hours of STEM (science, technology, engineering and math) instruction and provided workforce development to 5,500 individuals to help inspire and prepare the next-generation workforce. We provided 940,000 meals to the hungry. We planted 58,500 trees, including large scale, multi-year efforts in 5 countries.

**Information about our Executive Officers**

The following information is being furnished with respect to our executive officers as of February 4, 2026:

---

| | | |
|:---|:---|:---|
| **Name** | **Age** | **Position with the Company** <sup>(1)</sup> |
| Michael E. Alexander | 56 | Group President, Project Execution |
| Pierre Bechelany | 60 | Business Group President, Energy Solutions |
| James R. Breuer | 57 | Chief Executive Officer |
| Alvin C. Collins III | 52 | Business Group President, Mission Solutions |
| David E. Constable | 64 | Executive Chairman |
| Tracey H. Cook | 58 | Chief Human Resources Officer |
| Nicole Davies | 49 | Executive Vice President, Corporate Development & Sustainability |
| James P. Elliott | 47 | Chief Accounting Officer and Controller |
| Mark E. Fields | 67 | Group President, Strategic Projects |
| Kevin B. Hammonds | 54 | Chief Legal Officer and Corporate Secretary |
| Anthony Morgan | 59 | Business Group President, Urban Solutions |
| John C. Regan | 56 | Chief Financial Officer |

---

_______________________________________________________________________________

(1)All references are to positions held with Fluor Corporation. All officers serve in their respective capacities at the pleasure of the Board of Directors.

***Michael E. Alexander***

Mr. Alexander has been Group President, Project Execution since November 2025. Prior to that he was Business Group President, Energy Solutions from 2024 to 2025. Prior to that, he was President, Chemicals from 2019 to 2024 and President, Energy & Chemicals — Americas in 2019. He joined the company in 1991.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

***Pierre Bechelany***

Mr. Bechelany has been Business Group President, Energy Solutions since November 2025. Prior to that, he was President, LNG and Power — Energy Solutions from 2024 to 2025 and President, LNG — Energy Solutions from 2020 to 2023. He joined the company in 2010.

***James R. Breuer***

Mr. Breuer has been Chief Executive Officer since May 2025. Prior to that, he was Chief Operating Officer from 2024 to 2025, Business Group President, Energy Solutions from 2021 to 2024 and President, Downstream — Energy & Chemicals from 2019 to 2021. Mr. Breuer joined the company in 1993.

***Alvin C. Collins III***

Mr. Collins has been Business Group President, Mission Solutions since March 2025. Prior to that, he was Group President, Corporate Development and Sustainability from 2021 to 2025, Senior Vice President, Operations — Energy & Chemicals from 2019 to 2021 and Senior Vice President, Global Business Development — Energy & Chemicals in 2019. Mr. Collins joined the company in 1994.

***David E. Constable***

Mr. Constable has been Executive Chairman of the Board since May 2022. He was previously Chief Executive Officer of the company from January 2021 to May 2025, and has served as a member of Fluor's Board of Directors since 2019. He previously served as Chief Executive Officer (from 2011) and Chief Executive Officer and President (from 2014) of Sasol Ltd., an integrated energy and chemical company, until 2016. Mr. Constable first joined the company in 1982.

***Tracey H. Cook***

Ms. Cook has been Executive Vice President and Chief Human Resources Officer since April 2025. Prior to that, she was Senior Vice President, Human Resources from 2023 to 2025, and President of AMECO from 2014 to 2023. Ms. Cook joined the company in 1989.

***Nicole Davies***

Ms. Davies has been Executive Vice President, Corporate Development and Sustainability since March 2025. Prior to that, she was Senior Vice President, Business Development and Strategy — Energy Solutions from 2022 to 2025 and Vice President, Sales — Energy Solutions from 2019 to 2022. Ms. Davies joined the company in 1998.

***James P. Elliott***

Mr. Elliott was appointed Chief Accounting Officer in February 2026. He has been Corporate Controller since 2025. Prior to that, he was Director of Technical Accounting and Internal Reporting from 2019 to 2025. Mr. Elliott is a Certified Public Accountant recognized by the State of Texas. Mr. Elliott joined the company in 2019.

***Mark E. Fields***

Mr. Fields has been Group President, Strategic Projects since November 2025. Prior to that, he was Group President, Project Execution from 2021 to 2025 and Group President, Energy & Chemicals from 2019 to 2021. Mr. Fields joined the company in 1981.

***Kevin B. Hammonds***

Mr. Hammonds has been Executive Vice President and Chief Legal Officer since August 2024 and Corporate Secretary since May 2025. Prior to that, he was Senior Vice President, Managing General Counsel from 2020 to 2024 and Vice President, General Counsel from 2014 to 2020. He joined the company in 1996.

***Anthony Morgan***

Mr. Morgan has been Business Group President, Urban Solutions since January 2024. Prior to that, he was President, Mining & Metals from 2017 to 2023. Mr. Morgan joined the company in 1990.

***John C. Regan***

Mr. Regan has been Executive Vice President and Chief Financial Officer since March 2025. Prior to that, he was Executive Vice President, Controller and Chief Accounting Officer from 2020 to 2025. Mr. Regan is a Certified Public Accountant recognized by the State of Texas. Mr. Regan joined the company in 2020.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Available Information**

Our website address is *www.fluor.com*, where we provide free electronic copies of our annual reports on Form 10-K, quarterly reports on Form 10-Q, current reports on Form 8-K, and all amendments to those reports on the "Investor Relations" section as reasonably practicable after we electronically file them with, or furnish them to, the SEC. These reports, and any amendments to them, are also available at the SEC's website, *www.sec.gov*. We also use our investor relations website as a channel of distribution for important company information. Investors and others can receive notifications of new information posted on our investor relations website in real time by signing up for e-mail alerts. We also maintain information on our website related to our corporate governance including our Corporate Governance Guidelines, our Board Committee Charters and our Code of Business Conduct and Ethics for Members of the Board of Directors.

Website references are provided throughout this document for convenience. The content on the references websites does not constitute a part of and is not incorporated by reference into this Annual Report on Form 10-K.

**Item 1A.&nbsp;&nbsp;&nbsp;&nbsp;*Risk Factors***

*We operate in a complex and rapidly changing global environment that involves numerous known and unknown risks and uncertainties that could materially adversely affect our business, financial condition, results of operations, and stock price.* 

*In evaluating our business, you should carefully consider the following discussion of material risks, events and uncertainties that make an investment in us speculative or risky in addition to other information in this Annual Report on Form 10-K. The risks described below highlight some of the factors that have affected and could affect us in the future. We may also be affected by unknown risks or risks that we currently think are immaterial. If any such events actually occur, our business, financial condition, results of operations, and stock price could be materially adversely affected. The disclosures below reflect our beliefs and opinions as to factors, events or contingencies that could materially and adversely affect us and our securities in the future. References to past events are provided by way of example only and are not intended to be a complete listing or a representation as to whether or not such factors, events or contingencies have occurred in the past or their likelihood of occurring in the future.*

**<u>Summary Risk Factors</u>**

The following summarizes the risks and uncertainties that could materially adversely affect our business, financial condition, results of operation and stock price. You should read this summary together with the more detailed description of each risk factor contained below.

**Risks Related to our Operations**

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We are vulnerable to the cyclical nature of the markets we serve.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our revenue and earnings are largely dependent on new awards.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The nature of our contracts, particularly our lump-sum contracts, subject us to risks associated with delays and cost overruns, which may not be fully recoverable and may result in reduced profits or losses that could have a material impact on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Intense competition in the EPC industry can impact our revenue and profits.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our ability to operate profitably requires us to hire and retain qualified personnel.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The success of teaming arrangements and joint ventures depends on the satisfactory performance by our venture partners over whom we may have little or no control, and the failure of those partners to perform their obligations could impose additional obligations on us that could have a material impact on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We are dependent upon suppliers and subcontractors to complete many of our contracts.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Cybersecurity breaches of our systems and IT could adversely impact us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Systems and IT interruption, as well as new systems implementation, could adversely impact our ability to operate.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We may use artificial intelligence, machine learning, data science and similar technologies in our business, and challenges with properly managing such technologies could result in reputational harm, competitive harm, and legal liability, and adversely affect our business, financial condition and results of operations.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We have international operations that are subject to foreign economic and political uncertainties and risks. Unexpected and adverse changes in the foreign countries in which we operate could result in project disruptions, increased cost and potential losses.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our backlog is subject to unexpected adjustments and cancellations.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our employees work on projects that are inherently dangerous and in locations where there are high security risks, and a failure to maintain a safe work site could result in significant losses.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our businesses could be materially and adversely affected by events outside of our control.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our actual results could differ from the estimates used to prepare our financial statements.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our earnings are subject to volatility due to recurring fair value measurements of our investment in NuScale.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• If we experience delays or defaults in client payments, we could be negatively impacted.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Contracts with or funded by the U.S. federal government pose additional risks compared to contracts with or wholly-funded by private sector clients.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our effective tax rate and tax positions may vary.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• It can be very difficult and expensive to obtain the insurance we need for our business operations.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• If we do not have adequate indemnification for our nuclear services, it could adversely affect our business and financial condition.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Foreign currency risks could have an adverse impact on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The loss of one or a few clients could have an adverse effect on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our business may be negatively impacted if we are unable to adequately protect IP rights.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Climate-related events, natural disasters and related environmental issues could have a material adverse impact on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Increasing scrutiny and changing expectations from stakeholders with respect to sustainability practices may impose additional costs on us or expose us to reputational harm or other risks.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;**•** We may be unsuccessful in implementing our strategic initiatives.

**Risks Related to Indebtedness and Other Credit Related Risks** 

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Adverse credit and financial market conditions, including high interest rates, could impair our clients', our partners' and our own borrowing capacity, which could negatively affect us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The agreements governing our debt contain a number of restrictive covenants that limit our ability to engage in activities that may be in our interest or that create shareholder value.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our indebtedness could lead to adverse consequences or adversely affect our financial position and prevent us from fulfilling our obligations under such indebtedness, and any refinancing of this debt could be at significantly higher interest rates.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We may be unable to win new contract awards if we cannot provide clients with financial assurances.

**Legal and Regulatory Risks**

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We are involved in litigation and regulatory proceedings, potential liability claims and contract disputes that may have a material impact on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our failure to recover adequately on claims against project owners, subcontractors or suppliers for payment or performance could have a material effect on us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We could be adversely affected by violations of the U.S. Foreign Corrupt Practices Act and similar worldwide anti-bribery laws.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• We could be adversely impacted if we fail to comply with domestic and international import and export laws.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Employee, agent or partner misconduct or our overall failure to comply with laws or regulations could impair our ability to compete for contracts.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• New or changing legal requirements could adversely affect us.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Past and future environmental, safety and health regulations could impose significant additional costs on us.

**Risks Related to our Equity and Corporate Governance Documents**

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• If we issue additional equity securities, stockholders' ownership percentages would be diluted.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Delaware law and our charter documents may impede or discourage a takeover or change of control.

**<u>Risks Related to our Operations</u>**

***We are vulnerable to the cyclical nature of the markets we serve.***

The demand for our services is dependent upon our clients' capital investments. Our clients' interest in approving new projects, budgets for capital expenditures and need for our services have in the past been, and may in the future be, adversely affected by, among other things, poor economic conditions (including inflation, tariffs, slow growth or recession, changes to governments' fiscal or monetary policy and high interest rates), low or volatile oil and gas prices or other commodity prices, political uncertainties and currency fluctuations. Clients have been and remain selective in how they allocate their capital, especially the larger scale projects in which we specialize. For example, capital expenditures by our clients are influenced by factors such as prevailing hydrocarbon prices and expectations about future prices for underlying commodities, technological advances, the costs of exploration, production and delivery of product, domestic and international political, military, regulatory and economic conditions and other similar factors. There is no guarantee that current commodity prices will be sufficient to justify clients' capital expenditures, and the timing and extent of any future improvements in demand remain uncertain. The end markets we serve have historically been and will continue to be vulnerable to general downturns, which in turn could materially and adversely affect the demand for our services.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

***Our revenue and earnings are largely dependent on new awards.***

The award and timing of projects is unpredictable and driven by our clients. Awards, including expansions of existing projects, often involve complex and lengthy negotiations and competitive bidding processes. These processes can be impacted by a wide variety of factors including a client's decision to not proceed with the development of a project, governmental approvals, financing contingencies (including governmental support), commodity prices, environmental conditions and overall market and economic conditions. We do not always win contracts that we have bid on for a variety of reasons such as price, a client's perception of our ability to perform and/or perceived technology advantages held by others. Many of our competitors may be more inclined to take greater risks or include terms and conditions that we might not deem acceptable, especially when the markets for the services we typically offer are relatively soft. Because a significant portion of our revenue is generated from large projects, our results can fluctuate depending on whether and when large project awards occur and the commencement and progress of work under large contracts already awarded. As a result, we are subject to the risk of losing new awards to competitors or the risk that revenue may not be derived from awarded projects as quickly as anticipated. Additionally, uncertain economic and political conditions may make it difficult for our clients, our vendors and us to accurately forecast and plan future business activities. For example, changes to U.S. policies related to global trade and tariffs, and responsive changes in policy by foreign jurisdictions, have resulted in the past and may result in future uncertainty surrounding the global economy as well as retaliatory trade measures implemented by other countries. We cannot predict the outcome of changing trade policies or other unanticipated economic or political conditions, nor can we predict the timing, strength or duration of any worldwide economic recovery or downturn.

Following contract award, we may also encounter significant expense, delay, contract modification or even contract loss. Additionally, certain awards have been and may in the future be contested and/or otherwise involved in legal proceedings, inquiries or other similar developments outside of our control, which may result in significant delays in the project timeline or the wholesale cancellation or termination of a project. Any project delays, cancellations or contract modifications following the award of a contract could have an adverse effect on us.

***The nature of our contracts, particularly our lump-sum contracts, subject us to risks associated with delays and cost overruns, which may not be fully recoverable and may result in reduced profits or losses that could have a material impact on us.***

Because our projects are often technically complex, with multiple phases occurring over several years, we incur risks in our project execution activities. These risks could result in project delays, cost overruns or other problems and can include the following:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Evolving estimates related to productivity, scheduling estimates or future economic conditions, including with respect to the impacts of inflation and tariffs on lump-sum contracts;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Unanticipated technical problems, including design or engineering issues;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Inaccurate representations of site conditions and unanticipated changes in the project execution plan;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Project modifications creating unanticipated costs or delays and failure to properly manage project modifications;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Inability to achieve guaranteed performance or quality standards with regard to engineering, construction or project management obligations;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Insufficient or inadequate project execution tools and systems needed to record, track, forecast and control cost and schedule;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Reliance on historical cost and/or execution data that is not representative of current economic and/or execution conditions;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Failure to accurately estimate the timing and cost of projects, including due to inflation, tariffs, supply chain disruption, rising construction costs or unforeseen increases in the cost of labor;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Unanticipated increases in the cost of raw materials, components or equipment, including due to inflation or the imposition of tariffs;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Failure to properly make judgments in accordance with applicable professional standards, including engineering standards;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Failure to properly assess and update appropriate risk mitigation strategies and measures;

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Poor performance of our clients, partners, subcontractors, suppliers or other third parties;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Delays or productivity issues caused by climate-related events or other natural disasters; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Changes in local laws or difficulties or delays in obtaining permits, rights of way or other governmental approvals.

These and other risks have in the past, and may in the future, result in our failure to achieve contractual cost or schedule commitments, or to satisfy safety performance, overall client satisfaction or other performance criteria. As a result, we may receive lower fees or lose our ability to earn incentive fees. In other cases, our fee will not change but we will have to continue to perform work without additional revenue until the performance criteria is achieved. We may also incur liquidated damages if we fail to complete a project on its contractual timeline. In addition, if we fail to meet guaranteed performance or quality standards, we may be held responsible under the guarantee or warranty provisions of our contract for cost impact to the client, generally in the form of contractually agreed-upon liquidated damages or an obligation to re-perform work. To the extent these events occur, the total cost to the project (including any liquidated damages) could be material and could, in some circumstances, equal or exceed the full value of the contract. In such events, our financial condition or results of operations could be materially and negatively impacted.

In circumstances where the contract is lump-sum or the revenue is otherwise fixed, we bear significant risk for delays and cost overruns. Reimbursable contract types, such as those that include negotiated hourly billing rates, may restrict the kinds or amounts of costs that are reimbursable, therefore exposing us to the risk that we may incur certain costs in executing these contracts that are above our estimates and not recoverable from our clients.

***Intense competition in the EPC industry can impact our revenue and profits.***

We serve markets that are highly competitive and in which a large number of multinational companies compete. These markets require substantial resources, investment in technology and skilled personnel. We have seen a continuing influx of non-traditional competitors offering below-market pricing while accepting greater risk. Competition places downward pressure on our contract prices and profit margins, and could cause us to accept contractual terms and conditions that are not normal or customary, thereby increasing the risk of reduced profitability on such contracts. Intense competition is expected to continue in our markets, presenting us with challenges to maintain acceptable profit margins. To the extent we are unable to meet these competitive challenges, we could experience reduced profitability.

***Our ability to operate profitably requires us to hire and retain qualified personnel.***

The success of our business is dependent upon being able to attract, develop and retain personnel, including engineers, project management, craft employees and management, who have the necessary and required experience and expertise, and who will perform these services at a reasonable and competitive rate. Competition for experienced personnel can be intense. It may be difficult to attract and retain qualified individuals with the expertise and in the timeframe demanded by our clients. In certain geographic areas, for example, we may be unable to satisfy the demand for our services because of our inability to deploy qualified personnel. Also, it may be difficult to replace personnel who hold government required credentials. Loss of the services of, or failure to recruit, qualified technical and management personnel, could limit our ability to successfully complete existing projects and compete for new projects. In addition, as costs related to our workforce are dependent on market conditions, inflationary pressure has increased, and may continue to increase, labor costs in certain geographic areas.

As some of our executives and other key personnel approach retirement age or otherwise leave the company, we need to provide for smooth transitions, which requires succession planning to identify and integrate new personnel into leadership roles. Changes in our management team may disrupt our business and the failure to successfully transition and assimilate executives or other key personnel could adversely affect our results. If we are unable to employ a sufficient number of skilled personnel or effectively implement appropriate succession plans, our ability to pursue projects may be adversely affected and the costs of executing our existing and future projects may increase.

In addition, the cost of providing our services, including the extent to which we utilize our workforce, affects our profitability. For example, the uncertainty of contract award timing and unexpected award cancellations can present difficulties in matching our workforce size with project needs. If an expected contract award is delayed or not received, we could incur costs resulting from excess staff, reductions in staff, or redundancy of facilities that could have a material adverse impact on us. Increased labor costs can also impact our customers' decision making with respect to the viability or timing of certain projects, which could result in project delays or cancellations and in turn have a material adverse impact on us.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

***The success of teaming arrangements and joint ventures depends on the satisfactory performance by our venture partners over whom we may have little or no control, and the failure of those partners to perform their obligations could impose additional obligations on us that could have a material impact on us.***

In the ordinary course of business in our industry, we execute projects and otherwise conduct certain operations through joint ventures, partnerships and other collaborative arrangements (collectively, "ventures"). We have various ownership interests in these ventures, with such ownership typically being proportionate to our decision-making and distribution rights. The ventures generally contract directly with our client; however, services may be performed directly by the venture, or may be performed by us, our partners, or a combination thereof.

Our success in many markets is impacted by the presence or capability of our partners. If we are unable to compete alone, or with a quality partner, our ability to win work and successfully execute our projects may be impacted. Differences in opinions or views between venture partners can result in delayed decision-making or failure to agree on material issues, which could adversely affect the business and operations of our ventures. In many of the countries in which we engage in joint ventures, it may be difficult to enforce our contractual rights under the applicable joint venture agreement.

At times, we also participate in ventures with other parties. In such instances, we may have limited control over venture decisions and actions, including ICFR, which may have an impact on our business. If internal control problems arise within a venture, or if our venture partners have financial or operational issues, there could be a material impact on us.

The success of our ventures also depends, in large part, on the satisfactory performance by our venture partners of their obligations, including their obligation to commit working capital, equity or credit support as required by the venture and to support their indemnification and other contractual obligations. If our venture partners fail to satisfactorily perform their obligations, the venture may be unable to adequately perform or deliver its contracted services. Under these circumstances, we may be required to make additional investments and provide additional services to ensure the adequate performance and delivery of the contracted services and to meet any performance guarantees. From time to time, in order to establish or preserve a client relationship, or to better ensure venture success, we may accept risks or responsibilities for the venture that are not necessarily proportionate with the reward we expect to receive or that may differ from risks or responsibilities we would normally accept in our own operations. We may also be subject to joint and several liability under the contracts for venture projects. These additional obligations could result in reduced profits or, in some cases, increased liabilities or significant losses for us with respect to the venture, and in turn, our business and operations. In addition, a failure by a venture partner to comply with applicable regulations could negatively impact our business and reputation and could result in fines, penalties, suspension or, in the case of government contracts, even debarment.

***We are dependent upon suppliers and subcontractors to complete many of our contracts.***

Some of the work performed under our contracts is performed by third-party subcontractors. We also rely on third-party suppliers to provide much of the equipment and materials used for projects. If we are unable to hire qualified subcontractors or find qualified suppliers, our ability to successfully or timely complete a project could be impacted. If the amount we are required to pay for subcontractors or equipment and supplies exceeds what we have estimated, especially in lump-sum contracts, we may suffer losses on them. If a supplier or subcontractor fails to provide supplies, technology, equipment or services as required under a contract to us, our joint venture partner, our client or any other party involved in the project for any reason, or provides supplies, technology, equipment or services that are not an acceptable quality, we may be required to source those supplies, technology, equipment or services on a delayed basis or at a higher price than anticipated, which could impact our profitability. In addition, faulty workmanship, equipment or materials could impact the overall project, resulting in claims against us for failure to meet required project specifications. These risks may be intensified during an economic downturn if these suppliers or subcontractors experience financial difficulties or find it difficult to obtain sufficient financing to fund their operations or access to bonding, and are not able to provide the services or supplies necessary for our business. A failure by a third-party subcontractor or supplier to comply with applicable laws, rules or regulations could negatively impact our business and reputation and could result in fines, penalties, suspension, or in the case of government contracts, even debarment.

***Cybersecurity breaches of our systems and IT could adversely impact us.***

Our business depends on the secure processing, storage, and transmission of confidential and sensitive information, including personal data of our employees, subcontractors, suppliers, business partners and clients. The various administrative and technical controls we have implemented to protect our systems and data from unauthorized access, cyber-attacks, and other cybersecurity breaches and our endeavors to require our third-party providers to adhere to industry recognized security standards may be insufficient to prevent all cybersecurity breaches or cyber-attacks. The risk of a cybersecurity breach or cyber-attack applies to any company with whom we do business and could adversely affect us, particularly when working collaboratively in shared workspaces or computing environments. Our efforts to protect information on our network and put

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

technical and/or contractual measures in place to protect information exchanges with other third parties with whom we work may be unsuccessful, and we cannot control or manage the safety and security of any third-party computing environment. In addition, because the techniques used to obtain unauthorized access to IT networks and systems change frequently, we and others with whom we work may be unable to anticipate these techniques or implement adequate preventative measures. As cybersecurity threats become more sophisticated and difficult to detect, our ability to promptly prevent, detect and mitigate the effects of cyber-attacks and other cybersecurity breaches may be impacted, potentially resulting in material adverse effects.

In the event of a cybersecurity breach or cyber-attack, we may experience operational disruptions, financial losses, legal claims, and reputational damage. Additionally, it may take considerable time for us to investigate and evaluate the full impact of a cybersecurity breach or cyber-attack, which may inhibit our ability to provide prompt, full and reliable information about cybersecurity incidents to our clients, regulators and the public. We may also incur significant costs to remediate the effects of such incidents, including costs associated with investigating the incident, repairing or replacing damaged systems and compensating affected parties.

We may also be subject to legal and regulatory actions, investigations, and penalties related to cybersecurity breaches and the unauthorized disclosure of confidential information or personal data, which may result in significant fines, sanctions, and legal fees, as well as damage to our reputation and customer relationships. In addition, data protection and cybersecurity laws are continuously evolving at a rapid pace and on a global level, which add heightened risk and additional costs in assessing, implementing and managing compliance measures that affect business operations. Any failure to comply with these laws and regulations or an exposure of information covered by such laws and regulations, including, without limitation, in connection with a cybersecurity breach, could have a negative impact on us.

The insurance we maintain that specifically covers cybersecurity threats may not sufficiently cover all types of losses or claims that we might experience, including losses from delays in our ability to provide services to our customers, reputational harm or the costs to improve security against future similar threats or losses arising from the computing environments and systems managed by others.

***Systems and IT interruption, as well as new systems implementation, could adversely impact our ability to operate.***

We are heavily reliant on computer, information and communications technology and related systems, some of which are hosted by third-party providers. From time to time, we experience system interruptions and delays that may be planned for upgrades or that may be unplanned. Unplanned interruptions could result from natural disasters, power loss, telecommunications failures, acts of war or terrorism, errors or other defects in the design or implementation of the applicable system, computer viruses, malicious code, physical or electronic security breaches, intentional or inadvertent user misuse or error and similar events or disruptions. Any of these or other events could cause system interruptions, delays, loss of critical or sensitive data (including personal or financial data) or loss of funds; could delay or prevent operations (including the processing of transactions and reporting of financial results); and could adversely affect us. Safeguards designed to protect against unavailability or loss of data may not be sufficient. We may be required to incur significant costs to protect against or alleviate damage caused by systems interruptions and delays, which could have a material adverse effect on our business and results of operations.

We continue to evaluate the need to upgrade and/or replace our systems and network infrastructure to protect our computing environment, to stay current on vendor supported products, to improve the efficiency of our systems and for other business reasons. The implementation of new technology systems and tools could adversely impact our operations by imposing substantial capital expenditures, demands on management time, risks of delays, complications in setup or configuration or other difficulties in transitioning to new systems. Our systems implementations also may not result in productivity improvements at the levels anticipated. Disruptions, if not anticipated and appropriately mitigated, could have a material adverse effect on our business.

***We may use artificial intelligence, machine learning, data science and similar technologies in our business, and challenges with properly managing such technologies could result in reputational harm, competitive harm, and legal liability, and adversely affect our business, financial condition and results of operations.***

Artificial intelligence, machine learning, data science and similar technologies (collectively, "AI"), including third-party AI tools, may be enabled by, or integrated into, some of our business processes and solutions. As with many developing technologies, AI presents risks and challenges that could affect its further development, adoption, and use, and therefore our business. AI algorithms may be flawed or biased. Datasets used to train or develop AI systems may be insufficient, of inferior quality, or contain biased, or incorrect or incomplete information. The use of AI subjects us to additional risk and liability exposure relating to confidentiality, intellectual property infringement, and client use restrictions. Our AI governance review process and self-imposed requirement to implement safeguards before adopting AI may not be adequate to protect against

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

these risks and challenges. Additionally, the laws and regulations concerning the use of AI continue to evolve. If the use or integration of AI systems, or the outputs generated by such systems, were determined to be non-compliant (e.g., in relation to IP or data privacy rights or in relation to the deployment of AI for certain activities or use cases), this may adversely affect us. It is possible that emerging regulations may limit or block the use of AI in our business or otherwise impose restrictions that may adversely affect the efficiency of our business processes or solutions that were utilizing AI technologies.

The safeguards we have implemented, including policies and procedures, governance reviews, technical measures where feasible, and contractual obligations relating to the ethical use of AI, may not be adequate or effective, and we cannot guarantee or control how third parties with whom we do business may utilize AI, which subjects us to increased risk and exposure relating to confidentiality and information security and information accuracy. If a breach of confidentiality or error or defect were to occur as a result of using AI, directly or indirectly, it could adversely affect our business, reputation, financial condition and results of operations.

Our competitors may incorporate AI into their product and service offerings more quickly or more successfully than us, which could impair our ability to compete effectively and adversely affect our business, financial condition and results of operations.

***We have international operations that are subject to foreign economic and political uncertainties and risks. Unexpected and adverse changes in the foreign countries in which we operate could result in project disruptions, increased cost and potential losses.***

Our business is subject to international economic and political conditions that change (sometimes frequently) for reasons that are beyond our control. We expect that a significant portion of our revenue and profits will continue to come from non-U.S. projects for the foreseeable future.

Operating in the international marketplace exposes us to a number of risks including:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• abrupt changes in government policies, laws, treaties (including those impacting trade), regulations or leadership;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• embargoes or other trade restrictions, including sanctions;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• restrictions on currency movement;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• tax or tariff changes and withholding requirements;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• currency exchange rate fluctuations;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• changes in labor conditions and difficulties in staffing and managing international operations, including logistical and communication challenges;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• U.S. government trade or other policy changes in relation to the foreign countries in which we operate;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• other regional, social, political and economic instability, including recessions and other economic crises;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• natural disasters and public health crises, including pandemics;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• expropriation and nationalization of our assets or projects;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• international hostilities, such as the ongoing Russia-Ukraine conflict and political and economic instability and conflict in the Middle East; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• other unrest, civil strife, acts of war, terrorism and insurrection.

The lack of a well-developed legal system in some of the countries where we operate may make it difficult to enforce our contractual rights or to defend ourselves against claims made by others. We operate in locations where there is a significant amount of political risk. In addition, nationalization, military action or continued unrest could impact the supply or pricing of oil, disrupt our operations in the region and elsewhere, and increase our security costs. Any alleged or actual failure to comply with any sanctions or trade control measures implemented in response to international conflicts may subject us to government scrutiny, civil and/or criminal proceedings, sanctions and other liabilities. Our level of exposure to these risks may vary with each project, depending on the location of the project and its stage of completion. For example, our risk exposure with respect to a project in an early development phase, such as engineering, will generally be less than our risk exposure on a project that is in the construction phase. To the extent that our international business is affected by unexpected and adverse foreign economic and political conditions and risks, we may experience project disruptions and losses.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

***Our backlog is subject to unexpected adjustments and cancellations.***

Our backlog generally consists of projects for which we have an executed contract or commitment with a client and reflects our expected revenue from the contract or commitment, which is often subject to revision over time. There is no guarantee that the revenue projected in our backlog will be realized or profitable or will not be subject to delay or suspension. Project cancellations, scope adjustments or deferrals, or foreign currency fluctuations may occur with respect to contracts reflected in our backlog and could reduce the value of our backlog and the revenue and profits that we actually earn; or, may cause the rate at which we perform on our backlog to decrease. Most of our contracts have termination for convenience provisions in them allowing clients to cancel projects. Our contracts typically provide for the payment of fees earned through the date of termination and the reimbursement of costs incurred including demobilization costs. In addition, projects may remain in our backlog for an extended period of time. During periods of economic slowdown, or decreases and/or instability in oil and gas prices, the risk of projects being suspended, delayed or canceled generally increases. Finally, poor project execution could also impact our backlog and profits. Such developments could have a material adverse effect on us.

***Our employees work on projects that are inherently dangerous and in locations where there are high security risks, and a failure to maintain a safe work site could result in significant losses.***

We often work on complex projects, frequently in geographically remote or high-risk locations that are subject to political, social or economic risks, or war or civil unrest. In those locations where we have employees or operations, we may expend significant efforts and incur substantial security costs to maintain safety. In addition, our project sites can place our employees and others near large equipment, dangerous processes or substances or highly regulated materials, and in challenging environments. Safety is a primary focus of our business and is critical to our reputation and performance. Many of our clients require that we meet certain safety criteria to be eligible to bid on contracts, and some of our contract fees or profits are subject to satisfying safety criteria. Unsafe work conditions also have the potential of increasing employee turnover, increasing project costs and raising our operating costs. If we fail to implement appropriate safety procedures or if our procedures fail, our employees or others may suffer injuries or loss of life, the completion of a project could be delayed and we could experience investigations or litigation. The safety function we rely on to implement effective health, safety and environmental procedures throughout our company may be ineffective, and the failure to comply with such procedures, client contracts or applicable regulations could subject us to losses and liability. Despite these activities we cannot guarantee the safety of our personnel, nor can we guarantee our work, equipment or supplies will be free from damage.

***Our businesses could be materially and adversely affected by events outside of our control.***

Extraordinary or force majeure events beyond our control, such as natural or man-made disasters, severe weather conditions, public health crises, supply chain disruption, geopolitical conflicts, political crises or other catastrophic events, could negatively impact our ability to operate or increase our costs to operate. Such events may result in disruptions to our operations; evacuation of personnel; increased labor and material costs or shortages; inability to deliver materials, equipment and personnel to job sites in accordance with contract schedules; and loss of productivity. When making contract proposals, we rely heavily on our estimates of costs and timing to complete the associated projects, as well as assumptions regarding technical issues, but those estimates and assumptions may ultimately prove to be incorrect. Additionally, we may remain obligated to perform our services after any natural or human-caused events, unless certain contractual provisions allow for relief from such obligations. The extra costs incurred as a result of these events may not be reimbursed by our clients. If we are not able to react quickly to such events, or if a high concentration of our projects is impacted by such an event, our operations may be adversely affected. In addition, if we cannot complete our contracts on time, we may be subject to potential liability claims by our clients, which may reduce our profits and result in losses.

***Our actual results could differ from the estimates used to prepare our financial statements.***

In preparing our financial statements, we make estimates and assumptions that affect the reported values of assets, liabilities, revenue and expenses, and the disclosure of contingent assets and liabilities. Areas requiring development of significant estimates include:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• determination of profitability;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• recognition of project incentives, awards, change orders, claims or other variable consideration we expect to receive;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• estimated amounts for project losses, warranty costs, contract close-out or other costs;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• income tax provisions and related valuation allowances; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• accruals for other estimated liabilities, including litigation and insurance reserves and receivables.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Estimates are based on reasonable assumptions and experience, but are only estimates. Our actual business and financial results can differ from our estimates of such results due to changes in facts and circumstances, which can have a material negative impact on our financial condition and results of operations. Further, we recognize contract revenue as work on a contract progresses. The cumulative amount of revenue recorded on a contract at any point is that percentage of total estimated revenue that costs incurred to date bear to estimated total costs. Accordingly, contract revenue and total cost estimates are reviewed and revised as the work progresses. Adjustments are reflected in contract revenue in the period when such estimates are revised. Such adjustments are at times material and result in reduced profitability.

***Our earnings are subject to volatility due to recurring fair value measurements of our investment in NuScale.***

Since October 2024, we account for our investment in NuScale using the fair value option for equity method investments, under which we measure our investment at fair value on a recurring basis using the prevailing price of NuScale's stock on our balance sheet dates. The fair value of our investment in NuScale is subject to the fluctuations of NuScale's stock price, which subjects our consolidated earnings to volatility. The price of NuScale's stock has experienced significant volatility since it commenced trading in May 2022, and the volatility may continue in the future in response to many factors, including factors beyond the control of us or NuScale. As a result of the recurring fair value measurements, we may recognize non-cash gains or losses in future periods, some of which could be material.

***If we experience delays or defaults in client payments, we could be negatively impacted.***

Because of the nature of our contracts, we sometimes commit resources to projects prior to receiving payments from clients in amounts sufficient to cover expenditures as they come due. Some of our clients have found it difficult to pay our invoices timely, increasing the risk that our accounts receivable could become uncollectible and ultimately be written off. In certain cases, our clients for our large projects are project-specific entities that do not have significant assets other than their interests in the project. From time to time, it is difficult for us to collect payments owed to us by these clients. In addition, clients may request extension of the payment terms otherwise agreed to under our contracts. Delays in client payments may require us to make a working capital investment, which could impact our cash flows and liquidity. If a client fails to pay invoices on a timely basis or defaults, there could be a material adverse effect on our results of operations or liquidity.

***Contracts with or funded by the U.S. government pose additional risks compared to contracts with or wholly-funded by private sector clients.***

We have a significant portfolio of U.S. federal government contracts, including those that we have in place with the DOE and DOD. U.S. government contracts are subject to various uncertainties, including, but not limited to:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• significant delays in funding appropriations, reductions in spending and changes in budgetary priorities that could reduce demand for our services, cancel or delay federal projects, and result in the closure of federal facilities and significant personnel reductions;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• disruptions to departments or agencies (including as result of budget deficits, government shutdowns and federal sequestration) that could interrupt communications with departments and agencies, result in program cancellations, disruptions and/or stop work orders, limit the government's ability to make timely payments, and limit our ability to perform under existing contracts and compete for new projects;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• oversight audits by government agencies and profit and cost controls, which could result in withholding or delay of payments to us; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• changes in the federal administration and/or congressional leadership and other policy and economic changes that could adversely impact us.

The U.S. government is under no obligation to maintain program funding at any specific level, and funds for a program may even be eliminated. Our U.S. government clients may terminate or decide not to renew our contracts with little or no prior notice.

In addition, U.S. government contracts are subject to specific regulations such as the Federal Acquisition Regulation ("FAR"), the Truth in Negotiations Act, the Cost Accounting Standards ("CAS"), the Service Contract Act and Department of Defense security regulations. Failure to comply with any of these regulations and other government requirements may result in contract price adjustments, financial penalties or contract termination. Our U.S. government contracts are also subject to audits, cost reviews and investigations by U.S. government oversight agencies such as the U.S. Defense Contract Audit Agency (the "DCAA"). The DCAA reviews the adequacy of, and our compliance with, our internal controls and policies (including our labor, billing, accounting, purchasing, estimating, compensation and management information systems). The DCAA also has the ability to review how we have accounted for costs under the FAR and CAS. The DCAA presents its findings to the Defense

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Contract Management Agency ("DCMA"). Should the DCMA determine that we have not complied with the terms of our contract and applicable statutes and regulations, or if they believe that we have engaged in inappropriate accounting or other activities, payments to us may be disallowed or we could be required to refund previously collected payments. Additionally, we may be subject to criminal and civil penalties, suspension or debarment from future government contracts, and qui tam litigation brought by private individuals on behalf of the U.S. government under the False Claims Act, which could include claims for treble damages. These suits may remain under seal (and hence, be unknown to us) for some time while the government decides whether to intervene on behalf of the qui tam plaintiff. Furthermore, if we have significant disagreements with our government clients concerning costs incurred, negative publicity could arise, which could adversely affect our industry reputation and our ability to compete for new contracts in the government arena or otherwise.

Most U.S. government contracts are awarded through a rigorous competitive process. The U.S. government has increasingly relied upon multiple-year contracts with pre-established terms and conditions that generally require those contractors that have been previously awarded the contract to engage in an additional competitive bidding process for each task order issued under the contract. Such processes require successful contractors to anticipate requirements and develop rapid-response bid and proposal teams as well as dedicated supplier relationships and delivery systems to react to these needs. We face rigorous competition and significant pricing pressures in order to win these task orders. If we are not successful in containing costs or able to timely respond to government requests, we may not win additional awards. Moreover, even if we are qualified to work on a government contract, we may be impacted in our pursuit of work by government policies designed to protect small businesses or certain other types of contractors.

Many of our U.S. government contracts require security clearances. Depending upon the level of clearance required, security clearances can be difficult and time-consuming to obtain. If we or our employees are unable to obtain or retain necessary security clearances, we may not be able to win new business, and our existing government clients could terminate their contracts with us or decide not to renew them.

***Our effective tax rate and tax positions may vary.***

We are subject to income taxes where we do business. A change in tax laws, treaties or regulations, or their interpretation, in any country in which we operate could change our overall tax rate, which could have a material impact on our results of operations. In addition, significant judgment is required in determining our worldwide provision for income taxes and our judgments could prove inaccurate. There are many transactions and calculations where the ultimate tax determination is uncertain. We are regularly under audit by tax authorities, and our tax estimates and tax positions could be materially affected by many factors including the final outcome of tax audits and related litigation, the introduction of new tax accounting standards, legislation, regulations and related interpretations, our global mix of earnings, our ability to realize deferred tax assets and changes in uncertain tax positions. Future changes in our tax rate or adverse changes in tax laws could have a material adverse effect on us. We may also be exposed to limitations on our ability to reinvest earnings from operations in one country to fund our operations in other countries due to tax laws in different jurisdictions.

***It can be very difficult and expensive to obtain the insurance we need for our business operations.***

We maintain insurance both as a corporate risk management strategy and to satisfy the requirements of many of our contracts. Although we have been generally able to cover our insurance needs, there can be no assurances that we can secure all necessary or appropriate insurance in the future, or that such insurance can be economically secured. For example, catastrophic events can result in decreased coverage limits, more limited coverage, increased premium costs or deductibles. We also monitor the financial health of our insurance providers. Our insurance is purchased from a number of leading providers, often in layered insurance or quota share arrangements. If any of our third-party insurers fail, abruptly cancel our coverage or otherwise cannot satisfy their obligations to us, then our overall risk exposure and operational expenses could increase and our business operations could be interrupted.

***If we do not have adequate indemnification for our nuclear services, it could adversely affect our business and financial condition.***

We provide services to the DOE and the nuclear energy industry in the on-going maintenance and modification of nuclear facilities as well as decontamination and decommissioning activities of nuclear plants. The Price-Anderson Act generally indemnifies parties performing services to nuclear power plants and DOE contractors; however, not all of our activities are covered. Thus, if the Price-Anderson Act indemnification protections do not apply to our services, or if the exposure occurs outside of the U.S. in a region that does not have protections comparable to the Price-Anderson Act, we could be adversely affected by our client's refusal to contract with us, by our inability to obtain commercially reasonable insurance or third-party indemnification, or by the potentially significant monetary damages we could incur.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

***Foreign currency risks could have an adverse impact on us.***

Our contracts may subject us to foreign currency risk, particularly when project revenue is denominated in a currency different from its expected costs. Contracts may be denominated in different currencies at various points in time as a project progresses. We may attempt to minimize our exposure to foreign currency risk by obtaining contract provisions that protect us from foreign currency fluctuations and/or by implementing hedging strategies utilizing derivatives. However, these actions may not always eliminate all foreign currency risk, and as a result, our profitability or cash flows could be affected.

Our monetary assets and liabilities denominated in nonfunctional currencies are subject to remeasurement which introduces potential profit volatility. In addition, the U.S. dollar value of our backlog may from time to time increase or decrease significantly due to foreign currency volatility.

***The loss of one or a few clients could have an adverse effect on us.***

A few clients, including the U.S. government, state governments and governmental agencies comprise a significant portion of our revenue. Although we have long-standing relationships with our most significant clients, our clients may unilaterally reduce, fail to renew or terminate their contracts with us at any time. The loss of business from a significant client could have a material adverse effect on us.

***Our business may be negatively impacted if we are unable to adequately protect IP rights.***

Our success is impacted by our ability to differentiate our services through our technologies and know-how. This includes the ability to protect IP rights. We utilize a combination of patents, copyrights, trade secrets, confidentiality agreements and other contractual arrangements to protect our interests. However, these methods only provide limited protection and may not adequately protect our interests. Our employees, contractors and joint venture partners are subject to confidentiality obligations, but this protection may be inadequate to deter or prevent misappropriation of our confidential information and/or infringement of our IP rights. This can be especially true in certain foreign countries where IP does not have equivalent protections as in the U.S., or when our joint venture partner is a competitor who will gain access to our procedures and know-how while working with us in the performance of services.

Our clients require broad ownership rights in the work product and other materials we deliver. If we are unable to retain ownership of our IP and improvements thereto, it may affect our ability to provide similar services and other projects in the future, which could have a material adverse effect on us.

Our competitors or others may independently develop technology substantially similar to our trade secret technology or we may be unsuccessful in preserving our IP rights in the future. Our IP rights could be invalidated, circumvented, challenged or infringed upon. Litigation to determine the scope of IP rights, even if ultimately successful, could be costly and could divert management's attention.

In addition, our clients or other third parties may also provide us with their technology and IP. There is a risk that we may not sufficiently protect against improper use, access or dissemination and, as a result, we could be subject to claims and litigation and resulting liabilities, loss of contracts or other consequences that could have an adverse impact on us.

We also hold licenses from third parties utilized in our business operations. If we are no longer able to license such technology on commercially reasonable terms or otherwise, we could be adversely affected. When we license our IP to third parties, the scope of such license grant is generally limited. If such third party exceeds the scope of the license grant, and if we are unable to detect unauthorized use of our IP or otherwise take appropriate steps to enforce our rights, our revenue and margins will be adversely impacted, and the value of our IP portfolio may be adversely affected.

***Climate-related events, natural disasters and related environmental issues could have a material adverse impact on us.***

Climate-related events, such as the frequency and severity of storms, floods, wildfires, droughts, hurricanes, freezing conditions, and other natural disasters, may have short-term, intermediate and long-term impacts on our business, financial condition and results of operation. Our efforts to mitigate our business risks associated with climate-related events and natural disasters cannot eliminate those risks, and we recognize that there are inherent climate-related and environmental risks regardless of where we conduct our businesses. For example, a catastrophic natural disaster could negatively impact any of our office locations and our project locations. Access to clean water and reliable energy in the communities where we conduct our business is critical to our operations. Accordingly, a natural disaster has the potential to disrupt our and our clients' businesses and may cause us to experience work stoppages, supply chain disruptions, project delays, financial losses and additional costs to resume operations, including increased insurance costs or loss of cover, legal liability and reputational losses.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Further, climate-related and environmental risks span across the full spectrum of the markets we serve. The direct physical risks that climate-related events and environmental issues pose, such as rising sea levels and temperatures, and acute events, such as hurricanes, droughts and wildfires, are common to each of these industries. Our clients could face increased costs to maintain their assets, which could result in reduced profitability and fewer resources for strategic investment. These types of physical risks could in turn lead to transitional risks (i.e., the degree to which society responds to climate and environmental matters). For example, concerns about climate and environmental matters may result in activism, protests, legislation, international protocols or treaties, regulation or other restrictions on greenhouse gas emissions or that otherwise seek to address climate and environmental matters that could affect our clients, including those who (a) are involved in the exploration, production or refining of hydrocarbons, such as our Energy Solutions clients, (b) emit greenhouse gases through the combustion of hydrocarbons or (c) emit greenhouse gases through the mining, manufacture, utilization or production of materials or goods. Such actions could increase the costs of projects for us and our clients or, in some cases, prevent a project from going forward, thereby potentially reducing the need for our services, which would in turn have a material adverse impact on us. However, policy changes and climate legislation could also accelerate energy transition, including the development of carbon capture and storage projects, alternative transportation, alternative energy facilities, such as wind farms or nuclear reactors, or incentivize increased implementation of clean fuels projects, which could positively impact the demand for our services. We cannot predict when or whether any of these legislative proposals may become law or what effect they will have on us and our clients.

We will also continue to incur additional expenses implementing U.S. and international regulations requiring additional disclosures regarding GHG emissions and/or broader sustainability-related factors. Compliance with such regulations and the associated potential costs is complicated by various countries and regions following different approaches to the regulation of climate and environmental matters.

***Increasing scrutiny and changing expectations from stakeholders with respect to sustainability practices may impose additional costs on us or expose us to reputational harm or other risks.***

Investors, clients, governments and other stakeholders have continued to focus on the sustainability practices of companies, including practices with respect to human capital, emissions and environmental impact and political spending. Expectations and requirements evolve rapidly, vary in their support for or rejection of such matters, and are largely out of our control, and our sustainability initiatives and disclosures in response to such expectations and requirements may result in increased costs (including but not limited to increased costs related to compliance, stakeholder engagement, contracting, litigation and insurance), change in demand for certain services, change in our competitiveness, enhanced or modified compliance or disclosure obligations, or other adverse impacts to our business or results of operations, including reputational harm. While we have programs and initiatives in place related to our sustainability practices, investors may decide to reallocate capital or to not commit capital as a result of their assessment of our practices. In addition, our clients may require that we adhere to varying sustainability standards. Our failure to comply with investor or client standards, which are evolving and may differ, or if we are perceived to not have responded appropriately to the growing concern for, or opposition to, these issues could also cause reputational harm to our business and could have a material adverse effect on us. In addition, organizations that provide ratings information to investors on sustainability matters may have unfavorable views on us, which may lead to negative sentiment or divestment.

In addition, while we may create and publish voluntary disclosures regarding sustainability matters, many of the statements in those voluntary disclosures are based on expectations and assumptions that may not be representative of current or actual risks, including the costs associated therewith. Such expectations and assumptions are necessarily uncertain and may be prone to error or subject to misinterpretation given the long timelines involved and the lack of an established single approach to identifying, measuring and reporting on many sustainability matters. In addition, there are increasing and inconsistent levels of regulation, disclosure-related and otherwise, with respect to sustainability matters. For example, the Corporate Sustainability Reporting Directive in the European Union as well as new sustainability-related disclosure requirements in U.S. states and other jurisdictions require companies to provide significantly expanded sustainability and other climate-related disclosures. Requirements from the SEC, European or other regulators may require us to incur significant costs to comply and distract our management and Board of Directors. We may also face material risks from the potential reversal or modification of these regulations, and reversal or material modification of these regulations could lead to the loss of time and resources already invested to prepare for these requirements. Many of these costs may not be recoverable from our clients.

***We may be unsuccessful in implementing our strategic initiatives.***

Our ability to successfully execute strategic initiatives, including plans to monetize our remaining stake in NuScale, is subject to various risks and uncertainties, which may negatively impact the realization of expected benefits. We cannot predict the trading price of shares of NuScale's common stock and the market value of the NuScale shares are subject to market volatility and other factors beyond the control of us or NuScale, including general economic, financial and business

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

conditions. We intend to complete the sale of our shares in NuScale by the end of Q2 2026, but there can be no assurance regarding the ultimate timing of such monetization process. Unanticipated developments could delay, prevent of otherwise adversely affect the monetization process, including but not limited to financial market conditions.

**<u>Risks Related to Indebtedness and Other Credit Related Risks</u>**

***Adverse credit and financial market conditions, including high interest rates, could impair our clients', our partners' and our own borrowing capacity, which could negatively affect us.***

Our ability to access cash is important for the funding of our operations, investing in ventures, the servicing of our indebtedness, paying dividends and making acquisitions. To the extent that existing cash balances and operating cash flow, together with borrowing capacity under our credit facility, are insufficient to make investments or acquisitions or provide needed working capital, we may require additional financing from other sources. Our ability to obtain such additional financing will depend upon prevailing capital market conditions, including those arising due to events occurring in our industry, as well as conditions in our business and our operating results; and those factors may affect our efforts to negotiate terms that are acceptable to us. Furthermore, if global economic, industry, political or other market conditions adversely affect the financial institutions that provide credit to us, our ability to establish or draw upon our credit facility, or refinance borrowings as they mature, may be impacted. In addition, a downgrade in our credit rating could increase the cost of our borrowings or their refinancing, limit access to sources of financing or lead to other adverse consequences such as requirements for liens or other forms of financial assurance. If adequate funds are not available, or are not available on acceptable terms, we may be unable to make future investments, take advantage of acquisitions or other opportunities, or respond to competitive challenges.

In addition, adverse credit and financial market conditions, including high interest rates, also adversely affect our clients' and our partners' borrowing capacity, which could result in contract cancellations or suspensions, project award and execution delays, payment delays or defaults by our clients. These disruptions could materially impact us.

***The agreements governing our debt contain a number of restrictive covenants that limit our ability to engage in activities that may be in our interest or that create shareholder value.***

Our credit facility and the indentures governing our debt contain a number of significant covenants that impose operating and other restrictions on us and our subsidiaries. Such restrictions affect or will affect and, in many respects, limit or prohibit, among other things, our ability and the ability of some of our subsidiaries to:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• incur additional indebtedness;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• create liens;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• pay dividends and make other distributions in respect of our equity securities;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• make investments or other restricted payments;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• sell assets;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• enter into transactions with affiliates; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• effect mergers or consolidations.

In addition, our credit facility requires us to maintain specified financial covenants. A breach of any of these covenants could result in a default. If a default occurs, the relevant lenders could elect to accelerate payments due or decline access to the facility for further borrowings. If our operating performance declines, or if we are unable to comply with any covenant, we may need to obtain amendments to our credit agreements or waivers from the lenders to avoid default. These factors could have a material adverse effect on us.

***Our indebtedness could lead to adverse consequences or adversely affect our financial position and prevent us from fulfilling our obligations under such indebtedness, and any refinancing of this debt could be at significantly higher interest rates***.

Our indebtedness could have important consequences, including but not limited to:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• increasing our vulnerability to general adverse economic and industry conditions;

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• requiring us to dedicate a substantial portion of our operating cash flow to servicing our debt, thereby reducing the availability of cash to fund working capital, capital expenditures, acquisitions and investments and other general corporate purposes; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• limiting our flexibility in planning for, or reacting to, challenges and opportunities, and changes in our businesses and the markets in which we operate.

Our ability to service our debt will depend on our future operating performance and financial results, which may be subject to factors beyond our control, including general economic, financial and business conditions. If we do not have sufficient cash flow to service our debt, we may need to refinance all or part of our existing debt, borrow more money or sell securities or assets, some or all of which may not be available to us at acceptable terms or at all. In addition, we may need to incur additional debt in the future in the ordinary course. Although the terms of our credit agreements and our indentures allow us to incur additional debt, there are limitations which may preclude us from incurring the desired amount.

***We may be unable to win new contract awards if we cannot provide clients with financial assurances.***

It is a common industry practice for clients to require us to provide surety bonds, letters of credit, bank guarantees or other forms of financial assurance as credit enhancements. Surety bonds, letters of credit or guarantees indemnify our clients if we fail to perform our contractual obligations. Historically, we have had strong surety bonding capacity due to our credit ratings, but bonding is provided at the surety's sole discretion. In addition, because of the overall limitations in worldwide bonding capacity, we may find it difficult to access sufficient surety bonding capacity to meet our total surety bonding needs. For letters of credit, we have historically had adequate capacity under our existing credit facility, but any capacity that may be required in excess of our credit limits would be at our lenders' sole discretion. Failure to provide credit enhancements on terms required by a client may result in an inability to compete for or win a project.

**<u>Legal and Regulatory Risks</u>**

***We are involved in litigation and regulatory proceedings, potential liability claims and contract disputes that may have a material impact on us.***

We are subject to a variety of legal or regulatory proceedings, liability claims or contract disputes. Our operating activities expose us to claims against us by clients, subcontractors or suppliers for recovery of costs they incurred in excess of what they expected to incur, or for which they believe they are not contractually liable. We may be named as a defendant in legal proceedings where parties may make a claim for damages or other remedies with respect to our projects or other matters, including shareholder litigation. During times of economic uncertainty, especially with regard to our commodity-based clients, claim frequencies and amounts tend to increase.

In proceedings where it is determined that we have liability, we may not be covered by insurance or these liabilities may exceed our coverage. In addition, even where insurance is maintained for such exposure, the policies have deductibles resulting in our assuming exposure for a layer of coverage with respect to any such claims. Our professional liability coverage is on a "claims-made" basis covering only claims actually made during the policy period. Any liability not covered by our insurance, in excess of our insurance limits or, if covered by insurance but subject to a high deductible, could have a material adverse impact on us.

In other legal or regulatory proceedings, liability claims or contract disputes, we may be covered by indemnification agreements that may at times be difficult to enforce. Even if enforceable, it may be difficult to recover under these agreements if the indemnitor does not have the ability to financially support the indemnity. Litigation and regulatory proceedings are subject to inherent uncertainties, and unfavorable rulings could occur, including for monetary damages. If we were to receive an unfavorable ruling in a matter, our business and results of operations could be materially harmed. Such proceedings can also be costly, time-consuming, disruptive to operations and distracting to management, regardless of the outcome. Our estimates regarding loss contingencies related to pending proceedings may not be accurate, and we could be required to pay significantly more for certain proceedings than we currently anticipate.

***Our failure to recover adequately on claims against clients, subcontractors or suppliers for payment or performance could have a material effect on us.***

We occasionally bring claims against clients and partners for additional costs exceeding the contract price or for amounts not included in the original contract price. Similarly, we present change orders and claims to our subcontractors and suppliers. If we fail to properly provide notice or document the nature of change orders or claims, or are otherwise unsuccessful in negotiating a reasonable settlement, we could incur reduced profits, cost overruns and in some cases a loss on the project. These types of claims can occur due to matters such as owner-caused delays or changes from the initial project scope, which result in additional cost. These claims can result in lengthy and costly proceedings, and it is often difficult to

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

accurately predict when these claims will be fully resolved. When these types of events occur and while unresolved claims are pending, we may invest significant working capital in projects to cover cost overruns pending the resolution of the relevant claims. A failure to promptly recover on these types of claims could have a material adverse impact on our liquidity and financial results.

***We could be adversely affected by violations of the U.S. Foreign Corrupt Practices Act and similar worldwide anti-bribery laws.***

The U.S. Foreign Corrupt Practices Act, the U.K. Bribery Act of 2010 and similar anti-bribery laws in other jurisdictions generally prohibit companies and their intermediaries from making improper payments to officials or others for the purpose of obtaining or retaining business. We operate in many parts of the world that have experienced corruption to some degree and, in certain circumstances, strict compliance with anti-bribery laws may conflict with local customs and practices, and our policies mandating compliance with these anti-bribery laws may not be effective. There is no assurance that our efforts to train our personnel concerning anti-bribery laws and issues, our efforts to inform our partners, subcontractors, suppliers, agents and others who work for us or on our behalf, or our internal controls and procedures to monitor compliance will always protect us from possible reckless or criminal acts committed by our employees or agents. If we are found to be liable for anti-bribery law violations (either due to our own acts or our inadvertence, or due to the acts or inadvertence of others including our partners, agents, subcontractors or suppliers), we could suffer from criminal or civil penalties or other sanctions, including contract cancellations or debarment, and damaged reputation, any of which could have a material adverse effect on us. Litigation or investigations relating to alleged or suspected violations of anti-bribery laws, even if ultimately such litigation or investigations demonstrate that we did not violate anti-bribery laws, could be costly and could distract management.

***We could be adversely impacted if we fail to comply with domestic and international import and export laws.***

Our global operations require importing and exporting goods and technology across international borders on a regular basis. Our policies mandate strict compliance with U.S. and foreign international trade laws. To the extent we export technical services, data and products outside of the U.S., we are subject to regulations governing international trade and exports including but not limited to the International Traffic in Arms Regulations, the Export Administration Regulations and trade sanctions against embargoed countries, which are administered by the Office of Foreign Assets Control within the Department of Treasury. From time to time, we identify certain inadvertent or potential export or related violations. These violations may include, for example, transfers without required governmental authorization. A failure to comply with these laws and regulations could result in civil or criminal sanctions, including the imposition of fines, the denial of export privileges, and suspension or debarment from participation in U.S. government contracts.

***Employee, agent or partner misconduct or our overall failure to comply with laws or regulations could impair our ability to compete for contracts.***

Misconduct, fraud, non-compliance with applicable laws and regulations, or other improper activities by one of our employees, agents or partners could have a significant negative impact on our business and reputation. Such misconduct could include the failure to comply with anti-corruption, export control and environmental regulations; federal procurement regulations, regulations regarding the pricing of labor and other costs in government contracts and regulations regarding the protection of sensitive government information; regulations on lobbying or similar activities; regulations pertaining to the ICFR; and various other applicable laws or regulations. The policies and precautions we take to prevent and detect fraud, misconduct or failures to comply with applicable laws and regulations may not be effective, and we could face unknown risks or losses. Failure to comply with applicable laws or regulations or acts of fraud or misconduct could subject us to fines and penalties, cancellation of contracts, loss of security clearance and suspension or debarment from contracting with government agencies, which could damage our reputation, weaken our ability to win contracts and have a material adverse impact on us.

***New or changing legal requirements could adversely affect us.***

Our business and results of operations could be affected by the passage of laws, policies and regulations. The implementation of trade barriers, countervailing duties, or border taxes, or the addition, relaxation or repeal of laws, policies and regulations regarding the industries and sectors in which we work could result in a decline in demand for our services, or may make the manner in which we perform our services, less profitable. Furthermore, changes to existing trade agreements may impact our business operations. We cannot predict when or whether any of these various legislative and regulatory proposals may become law or what their effect will be on us and our clients.

***Past and future environmental, safety and health regulations could impose significant additional costs on us.***

We are subject to numerous environmental laws and health and safety regulations. Our projects can involve the handling of hazardous and other highly regulated materials, including nuclear and other radioactive materials, which, if

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

improperly handled or disposed of, could subject us to civil and criminal liabilities. It is impossible to reliably predict the full nature and effect of judicial, legislative or regulatory developments relating to health and safety regulations and environmental protection regulations applicable to our operations. The applicable regulations, as well as the length of time available to comply with those regulations, continue to develop and change. The cost of complying with regulations, satisfying any environmental remediation requirements for which we may be found responsible, or satisfying claims or judgments alleging personal injury, property damage or natural resource damages as a result of exposure to, or contamination by, hazardous materials, including as a result of commodities such as lead or asbestos-related products, could be substantial, may not be covered by insurance, could impact profitability and materially impact our operations.

We are subject to a number of regulations such as those from the U.S. Nuclear Regulatory Commission and non-U.S. regulatory bodies, such as the International Atomic Energy Commission and the European Union, which can have a substantial effect on our nuclear-related projects. Delays in receiving necessary approvals, permits or licenses, the failure to maintain sufficient compliance programs, and other problems encountered during construction (including changes to such regulatory requirements) could have an adverse effect on us.

A substantial portion of our business is generated either directly or indirectly as a result of federal, state, local and foreign laws and regulations related to environmental matters. A reduction in the number or scope of these laws or regulations, or changes in government policies regarding the funding, implementation or enforcement of such laws and regulations, could significantly reduce the size of one of our markets and limit our opportunities for growth or reduce our revenue below current levels.

**<u>Risks Related to our Equity and Corporate Governance Documents</u>**

***If we issue additional equity securities, stockholders' ownership percentages would be diluted.***

We may in the future issue additional equity securities to pay for potential acquisitions or to otherwise fund our corporate initiatives. If we do issue additional equity securities, the issuance may dilute our earnings per share and stockholders' percentage ownership, to the extent that our existing shareholders do not participate in the issuance.

***Delaware law and our charter documents may impede or discourage a takeover or change of control.***

Fluor is a Delaware corporation. Various anti-takeover provisions under Delaware law impose impediments on the ability of others to acquire control of us, even if a change of control would be beneficial to our stockholders. In addition, certain provisions of our charters and bylaws may impede or discourage a takeover. For example:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• stockholders may not act by written consent;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• there are various restrictions on the ability of a stockholder to call a special meeting or to nominate a director for election; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• our Board of Directors can authorize the issuance of preferred shares.

These types of provisions in our charters and bylaws could also make it more difficult for a third party to acquire us, even if the acquisition would be beneficial to our equity holders.

**Item 1B.&nbsp;&nbsp;&nbsp;&nbsp;*Unresolved Staff Comments***

None.

**Item 1C.&nbsp;&nbsp;&nbsp;&nbsp;*Cybersecurity***

***Risk Management and Strategy***

We maintain a cybersecurity program designed to assess, identify and manage risks from cybersecurity threats that may result in adverse effects on the confidentiality, integrity and availability of our information systems. Security, privacy, information governance and compliance professionals are assigned to administer the program with oversight by our senior management team.

We have integrated cybersecurity risk into our broader enterprise risk management framework. Our cyber risk program leverages internationally recognized standards as appropriate. We use a combination of technology controls, human oversight and processes to actively monitor and protect our network and systems. All employees participate in a number of information security training programs. Employees receive training on how to spot and report cyber risks and events through our global cybersecurity awareness program. In addition, we hold cybersecurity risk insurance.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

We engage outside experts to evaluate and review our cybersecurity programs. These external reviews include regular audits, threat assessments, vulnerability scans, simulated attacks and other advice regarding information security practices. We regularly conduct incident response exercises with key stakeholders.

To manage risks associated with third-party service providers, we typically require new vendors with access to our computing environment or access to confidential or sensitive data to undergo a risk assessment from our information security team. We conduct periodic reviews of these vendors to evaluate compliance with our cybersecurity policies. We strive to ensure that our contracts with such vendors require them to maintain security controls in line with industry best practices, applicable laws and our policies. We rely on vendors to notify us in a timely manner of material cybersecurity incidents, by virtue of the documents governing their relationship with us or applicable law.

***Governance***

Cybersecurity is overseen by our Board of Directors with assistance from the Audit Committee. Our Board of Directors receives quarterly reports from management which may address a broad range of cybersecurity and IT topics, including trends, regulatory developments, data security policies and practices, cybersecurity incidents, current and projected threat assessments and ongoing efforts to prevent, detect and respond to critical threats.

Our Audit Committee, which is responsible for oversight of cybersecurity risks, periodically reviews and discusses with management, including the Chief Information Officer ("CIO") and the Chief Information Security Officer ("CISO"), risk issues associated with cybersecurity and policies and controls intended to mitigate those risks.

Our CISO, who has extensive cybersecurity knowledge and skills gained from over 25 years of work experience, heads the team responsible for cybersecurity. Our CISO's team is responsible for leading enterprise-wide cybersecurity strategy, policy, standards and processes. The team includes senior professionals, many with more than 15 years of cybersecurity expertise and industry certifications such as Certified Information Security Systems Professional, CompTIA Security+, Global Information Assurance Certification, and Certified Ethical Hacker. Members of the team are provided with opportunities to attend external training, conferences, and other events to keep abreast of the latest cybersecurity trends. Our CISO receives ongoing updates from his team regarding the prevention, detection, mitigation, and remediation of cybersecurity incidents.

Our CISO meets with our Audit Committee at least annually to discuss cybersecurity risk and related issues. These meetings may encompass a broad range of topics, including:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• cybersecurity initiatives and strategies,

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• cybersecurity events,

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• emerging threats,

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• regulatory requirements, and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• industry standards.

In the event of a cybersecurity incident, we have an incident response plan which sets forth a framework to report and document such incidents to our cybersecurity incident response team. This framework aims to enable the response team to take actions to monitor, mitigate and remediate such incidents in a timely manner. Cybersecurity incidents are regularly reported to the CIO and CISO and certain critical events are reported to the CEO and the crisis management team comprised of senior executives. We also have protocols in place by which certain cybersecurity incidents are reported to the Board of Directors as part of their oversight of cybersecurity matters.

***Cybersecurity Risks, Threats and Material Incidents***

Risks from cybersecurity threats, including as a result of any previous cybersecurity incidents, have not materially affected us, including our business strategy, results or operations or financial condition, and we do not believe that such risks are reasonably likely to have such an effect over the long term. While we are not aware of any cybersecurity incidents through the date of this report that have materially affected us, there can be no guarantee that we will not be the subject of future material cybersecurity incidents. Additional information on cybersecurity risks we face can be found in Item 1A of this 10-K, which should be read in conjunction with the foregoing information.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Item 2.&nbsp;&nbsp;&nbsp;&nbsp;*Properties***

**Major Facilities**

Our global operations span 3.7 million rentable square feet across both owned and leased properties. Our executive offices are located at 6700 Las Colinas Boulevard, Irving, Texas. Given the dynamic nature of our business, the extent of facility utilization by specific segment varies and cannot be precisely stated. Additionally, some of our properties are leased or subleased to third-party tenants.

In addition to our significant facilities, we lease or own a number of individually smaller offices, warehouses and equipment yards strategically located worldwide. While we maintain a global presence, the following summarizes our more significant existing facilities:

---

| | |
|:---|:---|
| **Location** | **Interest** |
| **United States:** | |
| &nbsp;&nbsp;&nbsp;Greenville, South Carolina | Owned and Leased |
| &nbsp;&nbsp;Houston, Texas | Leased |
| &nbsp;&nbsp;&nbsp;Irving, Texas (Corporate Headquarters) | Owned |
| &nbsp;&nbsp;&nbsp;Southern California (Aliso Viejo and Long Beach) | Leased |
| **Canada:** | |
| &nbsp;&nbsp;&nbsp;Calgary, Alberta | Owned |
| &nbsp;&nbsp;&nbsp;Vancouver, British Columbia | Leased |
| **Latin America:** | |
| &nbsp;&nbsp;&nbsp;Santiago, Chile | Owned and Leased |
| **Europe, Africa and the Middle East:** | |
| &nbsp;&nbsp;&nbsp;Al Khobar, Saudi Arabia | Owned |
| &nbsp;&nbsp;Amsterdam, Netherlands | Owned |
| &nbsp;&nbsp;&nbsp;Farnborough, England | Owned and Leased |
| &nbsp;&nbsp;&nbsp;Gliwice, Poland | Owned and Leased |
| **Asia and Pacific Region:** | |
| &nbsp;&nbsp;Manila, Philippines | Owned and Leased |
| &nbsp;&nbsp;&nbsp;New Delhi, India | Leased |
| &nbsp;&nbsp;&nbsp;Perth, Australia | Leased |
| &nbsp;&nbsp;&nbsp;Shanghai, China | Leased |

---

**Item 3.&nbsp;&nbsp;&nbsp;&nbsp;*Legal Proceedings***

As part of our normal business activities, we are party to a number of legal proceedings and other matters in various stages of development. We periodically assess our liabilities and contingencies for these matters based upon the latest information available.

For information on legal proceedings and matters in dispute, see the Consolidated Financial Statements in this report.

**Item 4.&nbsp;&nbsp;&nbsp;&nbsp;*Mine Safety Disclosures***

Information concerning mine safety violations or other regulatory matters required by Section 1503(a) of the Dodd-Frank Wall Street Reform and Consumer Protection Act and Item 104 of Regulation S-K (17 CFR 229.104) is included in Exhibit 95.1 to this report.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**PART II**

**Item 5.&nbsp;&nbsp;&nbsp;&nbsp;*Market for Registrant's Common Equity, Related Stockholder Matters and Issuer Purchases of Equity Securities***

Our common stock is traded on the New York Stock Exchange under the symbol "FLR."

We have paid no dividends on our common stock since April 2020. Any future cash dividends will depend upon our results of operations, financial condition, cash requirements and such other factors as our Board of Directors may deem relevant.

At January 31, 2026, there were 2,859 stockholders of record of our common stock.

**Issuer Purchases of Equity Securities**

The following table provides information for the 3 months ended December 31, 2025 about purchases by the company of equity securities that have been registered pursuant to Section 12 of the Securities Exchange Act of 1934, as amended (the "Exchange Act").

---

| | | | | |
|:---|:---|:---|:---|:---|
| **<u>Period</u>** | **Total Number**<br>**of Shares**<br>**Purchased**<sup>(1)</sup> | **Average Price<br>Paid per<br>Share** | **Total Number of<br>Shares Purchased as<br>Part of Publicly<br>Announced Plans<br>or Programs** | **Maximum**<br>**Number of**<br>**Shares that May**<br>**Yet Be Purchased**<br>**Under Plans or**<br>**Programs**<sup>(2)</sup> |
| October 1 – October 31, 2025 |  | $— |  | 19226397 |
| November 1 – November 30, 2025 | 3298033 | 42.36 | 3298033 | 15928364 |
| December 1 – December 31, 2025 | 5862419 | 42.47 | 5862419 | 10065945 |
| &nbsp;&nbsp;&nbsp;Total | 9160452 | $42.43 | 9160452 |  |

---

_______________________________________________________________________________

(1)Consists of 9,160,452 shares of stock repurchased and canceled by us under our stock repurchase program for total consideration of $389 million.

(2)The share repurchase program was originally announced on November 3, 2011 and, as amended, totals 66,000,000 shares as of December 31, 2025. The Board approved an increase to the program by an additional 30,000,000 shares in February 2026. We may repurchase shares from time to time in open market or privately negotiated transactions, including through pre-arranged trading programs, at our discretion, subject to market conditions and other factors and at such time and in amounts that we deem appropriate. The share repurchase program has no fixed expiration date.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Performance Graph**

Set forth below is a performance graph comparing the cumulative total return (assuming reinvestment of dividends), in U.S. Dollars, for the calendar years ended December 31, 2021, 2022, 2023, 2024 and 2025 of $100 invested on December 31, 2020 in our common stock, the S&P MidCap 400 Index and the Dow Jones Heavy Construction Industry Group Index.

![1942](flr-20251231_g1.jpg)

---

| | | | | | | |
|:---|:---|:---|:---|:---|:---|:---|
| | Year Ended December 31, | Year Ended December 31, | Year Ended December 31, | Year Ended December 31, | Year Ended December 31, | Year Ended December 31, |
| | 2020 | 2021 | 2022 | 2023 | 2024 | 2025 |
| Fluor Corporation | $100.00 | $155.10 | $217.03 | $245.27 | $308.83 | $248.15 |
| S&P MidCap 400 Index | $100.00 | $124.73 | $108.37 | $126.13 | $143.65 | $154.40 |
| Dow Jones Heavy Construction Industry Group Index | $100.00 | $149.33 | $170.68 | $204.36 | $287.15 | $387.57 |

---

**Item 6. *[Reserved]***

**Item 7.&nbsp;&nbsp;&nbsp;&nbsp;*Management's Discussion and Analysis of Financial Condition and Results of Operations***

The following discussion and analysis should be read in conjunction with our financial statements. A discussion and analysis of the operating results of 2024 compared to 2023 are included in our 2024 10-K and have not been repeated in this 10-K.

We continue to see solid client engagement across our markets and a robust and diverse pipeline of opportunities, particularly where accelerated schedules and critical business needs are driving investment. While some clients are pacing commitments due to cost pressures or commodity price softness, our teams are actively advancing engineering and design work so projects can move quickly once final decisions are made. These timing shifts impacted 2025 results, but we remain focused on disciplined execution, cost management, and positioning our clients for long-term success.

**Developments in Our Business**

Revenue, profit and operating cash flow in 2025 was significantly impacted by a judgment on the long completed Santos project in Australia. We have appealed the Court decision and we are also working with our insurance carriers to address the obligations arising from the judgment and the costs related to the appeal. We recognized a reversal of revenue of $643 million during 2025, inclusive of committed insurance proceeds, representing the net payment to Santos made in the fourth quarter of 2025.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

We slowed our execution activities at our joint venture in Mexico beginning in the second quarter of 2025 through much of the third quarter to minimize our working capital exposure to the joint venture's primary customer. The customer made significant progress payments through December 2025, which allowed us to execute a controlled restart of our project execution activities.

Prior to November 2025, we converted 15 million of our 126 million NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares and sold all 15 million of those shares for net proceeds of $605 million. We converted the remaining 111 million of our NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares upon reaching agreement with NuScale in November 2025, including the following general attributes:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Conversion of the 111 million remaining ownership units into NuScale registered shares on a one-to-one basis;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• For open market sales, daily limitations on our NuScale sales that vary depending on defined blackout dates for NuScale;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Voting covenant whereby we will agree to affirmatively support the expansion of NuScale's authorized share count by up to 330 million shares;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Imposition of NuScale trading limitations on any newly authorized shares through February 2026;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• 50% reduction in our benefits, if any, that may arise under the tax receivable agreement with NuScale;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Modification of our exclusivity arrangement with NuScale; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Various mutual releases and non-disparagement provisions.

In November 2025, through an indirect, wholly-owned subsidiary, we entered into a variable price forward sale agreement whereby we pledged and granted a security interest in 71 million of our remaining shares in NuScale, while maintaining continuing involvement and ownership rights, and committed to sell, convey, transfer, assign and deliver those shares at the final settlement date in the first quarter of 2026. Through our bank's execution, we completed the sale of all 71 million shares of NuScale on February 13, 2026, generating total proceeds of $1.35 billion. We expect to monetize the remaining 40 million shares of NuScale via similar structured programs and expect that all remaining ownership in NuScale should be sold by the second quarter of 2026.

Our divestiture of the Stork business was substantially completed following the sale of Stork's U.K. operations in 2025. Stork's operations in continental Europe were sold in 2024.

In December 2025, we reached an agreement to sell our ownership in the fabrication yard in China for approximately $122 million. The sale is expected to close in 2026, subject to the conditions in the agreement.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Results of Operations**

---

| | | | | | | |
|:---|:---|:---|:---|:---|:---|:---|
| | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** |
| ***(in millions)*** | **2025** | **2025** | **2024** | **2024** | **2023** | **2023** |
| **Revenue**<sup>(1)</sup> |  |  |  |  |  |  |
| &nbsp;&nbsp;&nbsp;Urban Solutions | $9200 |  | $7239 |  | $5262 |  |
| &nbsp;&nbsp;&nbsp;Energy Solutions | 3554 |  | 5976 |  | 6307 |  |
| &nbsp;&nbsp;&nbsp;Mission Solutions | 2720 |  | 2594 |  | 2655 |  |
| &nbsp;&nbsp;&nbsp;Other | 29 |  | 506 |  | 1250 |  |
| **Total revenue** | $15503 |  | $16315 |  | $15474 |  |
| **Segment profit (loss) $ and margin %** |  |  |  |  |  |  |
| &nbsp;&nbsp;&nbsp;Urban Solutions | $205 | 2.2% | $304 | 4.2% | $268 | 5.1% |
| &nbsp;&nbsp;&nbsp;Energy Solutions | (414) | NM | 256 | 4.3% | 381 | 6.0% |
| &nbsp;&nbsp;&nbsp;Mission Solutions | 94 | 3.5% | 153 | 5.9% | 116 | 4.4% |
| &nbsp;&nbsp;&nbsp;Other | 6 | NM | (78) | NM | (228) | NM |
| **Total segment profit (loss) $ and margin %**<sup>(2)</sup> | $(109) | (0.7)% | $635 | 3.9% | $537 | 3.5% |
| G&A | (196) |  | (203) |  | (232) |  |
| Foreign currency gain (loss) | (62) |  | 92 |  | (98) |  |
| Interest income (expense), net | 67 |  | 150 |  | 168 |  |
| Earnings (loss) attributable to NCI  | (11) |  | (61) |  | (60) |  |
| Earnings (loss) before taxes | (311) |  | 613 |  | 315 |  |
| Income tax benefit (expense) (including $92 million and $(376) million attributable to equity method earnings in 2025 and 2024, respectively)  | 39 |  | (634) |  | (236) |  |
| Net earnings (loss) before equity method earnings | (272) |  | (21) |  | 79 |  |
| Equity method earnings | 210 |  | 2105 |  |  |  |
| Net earnings (loss) | (62) |  | 2084 |  | 79 |  |
| Less: Net earnings (loss) attributable to NCI | (11) |  | (61) |  | (60) |  |
| **Net earnings (loss) attributable to Fluor** | (51) |  | 2145 |  | 139 |  |
| Less: Dividends on CPS |  |  |  |  | 29 |  |
| Less: Make-whole payment on conversion of CPS |  |  |  |  | 27 |  |
| Net earnings (loss) available to Fluor common stockholders | $(51) |  | $2145 |  | $83 |  |
| **New awards** |  |  |  |  |  |  |
| Urban Solutions | $8688 |  | $9493 |  | $10141 |  |
| Energy Solutions | 1421 |  | 3246 |  | 6871 |  |
| Mission Solutions | 1847 |  | 1910 |  | 1055 |  |
| Other |  |  | 474 |  | 1461 |  |
| **Total new awards** | $11956 |  | $15123 |  | $19528 |  |
| New awards related to projects located outside of the U.S. | 26% |  | 38% |  | 76% |  |
| **(in millions)** | **December 31, 2025** |  | **December 31, 2024** |  |  |  |
| **Backlog** <sup>(3)(4)</sup> |  |  |  |  |  |  |
| Urban Solutions | $18746 |  | $17749 |  |  |  |
| Energy Solutions | 4601 |  | 7605 |  |  |  |
| Mission Solutions | 2189 |  | 2727 |  |  |  |
| Other |  |  | 403 |  |  |  |
| **Total backlog** | $25536 |  | $28484 |  |  |  |
| Backlog related to projects located outside of the U.S. | 40% |  | 55% |  |  |  |
| Backlog related to reimbursable projects | 81% |  | 79% |  |  |  |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

(1)In addition to the measurements under GAAP, we measure our performance by analyzing trends in adjusted net revenue (and related margin), which we determine by reducing GAAP revenue to exclude at-cost revenue associated with reimbursable contracts for the following elements, where applicable:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• amounts associated with unaffiliated subcontractor project costs that are billed to clients without meaningful markup;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• amounts associated with costs of material that are billed to clients without meaningful markup; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• costs of CFM that are procured by our clients and which do not give rise to meaningful markup to our billings to clients.

Such at-cost revenue is generally reflected in our project estimates at equivalent amounts within the revenue and cost elements. Therefore, we believe our adjusted net revenue represents the basis for which we earn fees for our professional services. Others in our industry may have similar terms that they use to similarly measure the earnings power of their services. Even though our involvement with at-cost revenue elements as a principal gives rise to their inclusion in our consolidated revenue, the absence of meaningful markup to them elevates the importance of this non-GAAP analysis. During 2025 and 2024, at-cost revenue was approximately $8 billion and $7 billion, respectively (or approximately 53% and 40% of consolidated revenue). Excluding the amounts of at-cost revenue from both GAAP revenue and from project cost yields an amount that we call adjusted net margin.

(2)Total segment profit and margin are non-GAAP financial measures. We believe that total segment profit provides a meaningful perspective on our results as it is the aggregation of individual segment profit measures that we use to evaluate and manage our performance.

(3)During 2025, our backlog decreased due to the execution pace exceeding new award activity. We booked a multi-billion dollar award for a life sciences project during 2025. We booked significant positive project adjustments related to scope increases on several large projects during the second quarter of 2025 and scope reductions on 2 large projects in the first quarter of 2025.

Backlog represents the total amount of revenue we expect to record in the future based upon contracts that have been awarded to us. Backlog is stated in terms of gross revenues and may include significant estimated amounts of third-party, subcontracted, CFM and pass-through costs as well as other forms of variable consideration. For projects related to proportionately consolidated joint ventures, we include only our percentage ownership of each joint venture's backlog. We do not report new awards or backlog for projects related to our equity method investments even though these awards may be significant contributors to earnings in future periods. We recognize new awards into backlog when we and our client have approved the contract (written or verbal) and are committed to perform our respective obligations. Although backlog reflects business that is considered to be firm, cancellations, deferrals or scope adjustments may occur. Backlog is adjusted to reflect any known project cancellations, revisions to project scope and cost, foreign currency exchange fluctuations and project deferrals, as appropriate. Backlog differs from RUPO discussed elsewhere in this 10-K. Backlog includes the amount of revenue we expect to recognize under ongoing operations and maintenance contracts for the remainder of the current year renewal period plus up to 3 additional years if renewal is considered to be probable, while RUPO includes only the amount of revenue we expect to recognize under contracts with definite terms and substantive termination provisions. In 2026, we expect to execute approximately half of our ending 2025 backlog.

(4)Includes backlog of $255 million and $702 million for legacy projects in a loss position as of December 31, 2025 and 2024, respectively.

Revenue decreased in 2025 primarily due to the reversal of previously recognized revenue of $643 million for a judgment on the long-completed Santos project in Australia as well as a decline in execution activity for Energy Solutions projects nearing completion. However, revenue in both Urban Solutions and Mission Solutions increased in 2025 due to the ramp up of execution activities on life sciences and mining and metals projects and an increase in volume on a DOE project.

Earnings before taxes decreased during 2025 due to the same factors that impacted revenue above as well as cost growth on 3 infrastructure projects for subcontracted design errors, price escalation and schedule impacts.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Net earnings (loss) excluding amounts attributable to equity method earnings were as follows:

---

| | | | | |
|:---|:---|:---|:---|:---|
| | **YEAR ENDED<br> DECEMBER 31,** | **YEAR ENDED<br> DECEMBER 31,** | **YEAR ENDED<br> DECEMBER 31,** | **YEAR ENDED<br> DECEMBER 31,** |
| ***(in millions)*** | **2025** | **2025** | **2024** | **2024** |
| Earnings (loss) before taxes | $(311) |  | $613 |  |
| Income tax benefit (expense) | 39 |  | (634) |  |
| Less: Income tax benefit (expense) attributable to equity method earnings | 92 |  | (376) |  |
| Income tax expense and effective tax rate, excluding amount attributable to equity method earnings | (53) | *(17) %* | (258) | *42 %* |
| Net earnings (loss) excluding amount attributable to equity method earnings | $(364) |  | $355 |  |
| Equity method earnings | $210 |  | $2105 |  |
| Income tax benefit (expense) and effective tax rate attributable to equity method earnings | 92 | *(44) %* | (376) | *18 %* |
| Equity method earnings, net of related income tax expense | $302 |  | $1729 |  |
| Net earnings (loss) | $(62) |  | $2084 |  |

---

The effective tax rate on earnings, including equity method earnings, was 39%, 103% and 75% for 2025, 2024 and 2023, respectively. A reconciliation of U.S. statutory federal tax expense to total income tax expense follows:

---

| | | |
|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2025** |
| &nbsp;&nbsp;U.S. statutory federal tax expense (includes equity method earnings) | $(21) | 21% |
| &nbsp;&nbsp;&nbsp;Increase (decrease) in taxes resulting from: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;State and local income taxes | 61 | (60)% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign tax effects: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Australia |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Valuation allowance | 34 | (34)% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other | (11) | 11% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other foreign jurisdictions  | 60 | (59)% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Valuation allowance | (130) | 129% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign tax credits | (56) | 55% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;NCI |  | —% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other, net | 24 | (24)% |
| &nbsp;&nbsp;Total income tax benefit | $(39) | 39% |

---

In July 2025, the OBBB Act, which includes a broad range of U.S. tax reforms, was signed into law. The OBBB Act did not have a material impact on our consolidated results.

Our results were significantly impacted by evolving foreign currency rates in 2025. During 2025, the U.S. dollar depreciated against the Euro, British Pound, Canadian Dollar and Mexican Peso.

Our profit margin percentages may be favorably or unfavorably impacted by a change in the amount of CFM recorded. We record revenue on a gross basis, including CFM, when we have concluded that we are a principal with respect to such materials and services, though the timing of CFM receipt can significantly impact completion percentage.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Segment Operations** 

***Urban Solutions***

Revenue increased in 2025 due to the ramp up of execution activities on life sciences and mining and metal projects. The increase in 2025 revenue was partially offset by a decline in execution activity for recently completed projects and projects nearing completion. During 2025 and 2024, at-cost revenue for Urban Solutions was approximately $5 billion and $4 billion, respectively (or approximately 59% and 51% of their segment revenue).

Segment profit in 2025 decreased due to forecast adjustments for cost growth on 3 infrastructure projects related to subcontracted design errors, price escalation, schedule impacts partially offset by the refinement of expected recovery on these same projects. These forecast adjustments of $108 million were partially offset by improved performance on other infrastructure projects, a favorable negotiation with a designer on a separate infrastructure project and the ramp up of life sciences projects. The changes in segment profit margin in 2025 reflect these same factors.

New awards in 2025 included a large multi-billion dollar pharmaceutical facility, two significant mining projects and construction contracts for 2 infrastructure projects. Backlog increased in 2025 due to the new award activity. Our staffing business does not report new awards or backlog.

*Results for the fourth quarter of 2025.* Segment profit in the fourth quarter of 2025 decreased due to a portion of the forecast adjustments for cost growth on the infrastructure projects discussed above.

***Energy Solutions***

Revenue decreased in 2025 primarily due to the reversal of previously recognized revenue of $643 million for a judgment on the long completed Santos project in Australia. The revenue decrease was further driven by a decline in execution activity for several projects nearing completion and for certain projects at our joint venture in Mexico where we slowed our execution activities beginning in the second quarter of 2025 through much of the third quarter as previously discussed. The customer made significant progress payments in the latter half of 2025, which allowed us to execute a controlled restart of our project execution activities. The declines in revenue were partially offset by the ramp up of execution activities on a batteries project in Poland. During both 2025 and 2024, at-cost revenue for Energy Solutions was approximately $2 billion (or approximately 49% and 37% of their segment revenue).

Segment profit and profit margin declined in 2025 due to the judgment on the Santos project.

New awards were lower in 2025 compared to 2024. Backlog declined during 2025 due to the execution pace exceeding new award activity.

*Results for the fourth quarter of 2025.* Segment profit in the fourth quarter of 2025 was consistent with the fourth quarter of 2024.

***Mission Solutions***

Revenue increased in 2025 primarily due to an increase in project execution volume associated with a construction project for the DOE and hurricane claims administration support for FEMA, partially offset by reduced volumes on 2 DOE projects. Revenue in 2025 also included the recognition of revenue reserves for certain disputed costs on a DOD project and an adverse ruling on a long-standing claim for a project completed in 2019. During both 2025 and 2024, Mission Solutions had no meaningful amounts of at-cost revenue.

Segment profit and profit margin declined in 2025 primarily due to the recognition of revenue reserves for certain disputed costs on a DOD project and an adverse ruling on a long-standing claim for a project completed in 2019.

New awards in 2025 were stable with 2024 and included a six-year contract to extend our presence at the Portsmouth site. Backlog included $1.0 billion and $665 million of unfunded government contracts as of December 31, 2025 and 2024, respectively. Unfunded backlog reflects our estimate of future revenue under awarded government contracts for which funding has not yet been appropriated. We do not report new awards or backlog for projects related to our equity method investments even though these awards may be significant contributors to earnings in future periods.

*Results for the fourth quarter of 2025.* Segment profit in the fourth quarter of 2025 decreased due to the recognition of revenue reserves for certain disputed costs on a DOD project.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

***Other***

Prior to its deconsolidation in October 2024, the results of NuScale were presented in our Other segment. In 2025, we completed the sale of Stork's operations in the U.K. and recognized a gain on sale of $7 million compared to an $11 million gain on the sale of Stork's operations in continental Europe in 2024. The results from our Other segment were immaterial for 2025.

***G&A***

---

| | | | |
|:---|:---|:---|:---|
| | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** |
|<br>***(in millions)*** | **2025** | **2024** | **2023** |
| G&A |  |  |  |
| &nbsp;&nbsp;&nbsp;Compensation | $99 | $143 | $165 |
| &nbsp;&nbsp;&nbsp;Severance and restructuring costs | 43 | 13 | 11 |
| &nbsp;&nbsp;&nbsp;Legal & professional fees | 24 | 13 | 10 |
| &nbsp;&nbsp;&nbsp;Facilities | 7 | 15 | 14 |
| &nbsp;&nbsp;&nbsp;Reserve for legacy legal claims | 4 |  | 3 |
| &nbsp;&nbsp;&nbsp;Other | 19 | 19 | 29 |
| G&A | $196 | $203 | $232 |

---

The decrease in compensation expense in 2025 was primarily driven by lower stock price-driven compensation and performance-based compensation. During 2025, we recognized severance and exit costs primarily related to certain international office closures.

***Net Interest Income (Expense)***

The decrease in net interest income during 2025 was primarily due to a decrease in interest rates as well as cash balances at certain of our larger joint ventures.

***Equity Method Earnings***

---

| | | |
|:---|:---|:---|
| | **YEAR ENDED DECEMBER 31,** | **YEAR ENDED DECEMBER 31,** |
|<br>***(in millions)*** | **2025** | **2024** |
| Equity method earnings |  |  |
| &nbsp;&nbsp;&nbsp;Gain (loss) on the fair value of our investment in NuScale | $(419) | $2221 |
| &nbsp;&nbsp;&nbsp;Gain on the fair value of the forward sale contract of NuScale shares | 208 |  |
| &nbsp;&nbsp;&nbsp;Gain on the sale of NuScale shares | 336 |  |
| &nbsp;&nbsp;&nbsp;Other | 85 | (116) |
| Equity method earnings | $210 | $2105 |

---

**Critical Accounting Policies and Estimates**

Our discussion and analysis of our financial condition and results of operations is based upon our financial statements, which have been prepared in accordance with accounting principles generally accepted in the United States. Our significant accounting policies are described in the notes to our financial statements. The preparation of our financial statements requires management to make estimates and judgments that affect the reported amounts of assets, liabilities, revenue and expenses, and related disclosure of contingent assets and liabilities. Estimates are based on information available through the date of the issuance of the financial statements and, accordingly, actual results in future periods could differ from these estimates. Significant judgments and estimates used in the preparation of our financial statements apply to the following critical accounting policies:

*Revenue Recognition for Engineering & Construction Contracts.* We recognize our engineering and construction contract revenue over time as we provide services to satisfy our performance obligations. We generally use the cost-to-cost percentage-of-completion measure of progress as it best depicts how control transfers to our clients. The cost-to-cost approach measures progress towards completion based on the ratio of cost incurred to date compared to total estimated contract cost. Use of the cost-to-cost measure of progress requires us to prepare estimates of total expected revenue and cost to complete our projects.

CFM are included in revenue and cost of revenue when (1) we believe that we are acting as a principal rather than as an agent, (2) the contract includes construction activity and (3) we have visibility into the amount the customer is paying for the materials or there is a reasonable basis for estimating the amount. If we lose visibility mid-project, we cease recognizing

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

future CFM but do not de-recognize previous amounts of CFM.

Due to the nature of our industry, there is significant complexity in our estimation of total expected revenue and cost, for which we must make significant judgments. Our contracts with our customers may contain several types of variable consideration, including claims, unpriced change orders, award and incentive fees, liquidated damages and penalties or other provisions that can either increase or decrease the contract price to arrive at estimated revenue. Certain variable consideration, such as award and incentive fees, generally are awarded upon achievement of certain performance metrics, program milestones or cost targets and can be based upon customer discretion. We estimate variable consideration at the most likely amount to which we expect to be entitled upon completion of a project. We include estimated amounts in the transaction price to the extent it is probable we will realize that amount. Our estimates of variable consideration and our determination of its inclusion in project revenue are based on an assessment of our anticipated performance and other information that may be available to us.

At a project level, we have specific practices and procedures to review our estimate of total revenue and cost. Each project team reviews the progress and execution of our performance obligations, which impact the project's accounting outcome. As part of this process, the project team reviews information such as any outstanding key contract matters, progress towards completion and the related program schedule and identified risks and opportunities. The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our project estimates, which can change from period to period due to a variety of factors including:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Complexity in original design;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Extent of changes from original design;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Different site conditions than assumed in our bid;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The productivity, availability and skill level of labor;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Weather conditions when executing a project;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The technical maturity of the technologies involved;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Length of time to complete the project;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Availability and cost of equipment and materials;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Subcontractor and joint venture partner performance;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Expected costs of warranties; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our ability to recover for additional contract costs.

We recognize changes in contract estimates on a cumulative catch-up basis in the period in which the changes are identified. Such changes in contract estimates can result in the recognition of revenue in a current period for performance obligations which were satisfied or partially satisfied in prior periods. Changes in contract estimates may also result in the reversal of previously recognized revenue if the current estimate adversely differs from the previous estimate. If we estimate that a project will have costs in excess of revenue, we recognize the total loss in the period it is identified.

*Fair Value Measurements.* We elected the fair value option of accounting for our investment in NuScale that would have otherwise been recorded under the equity method of accounting. We recognize the fair value of our investment in NuScale on a mark-to-market basis based upon the prevailing price of their stock on our balance sheet dates, which may subject our consolidated earnings to volatility. We recognize the fair value of our forward sale contract in NuScale shares based on the difference between the closing price of NuScale at December 31, 2025 and the year-to-date settlement price calculated per the agreement plus a discounted growth assumption through the estimated settlement date. No estimates are used in the determination of the fair value of our investment in NuScale or the forward sale contract.

**Recent Accounting Pronouncements**

Item is described in the Notes to Financial Statements.

**Litigation and Matters in Dispute Resolution**

Item is described in the Notes to Financial Statements.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**LIQUIDITY AND CAPITAL RESOURCES**

Our liquidity arises from available cash and cash equivalents and marketable securities, cash generated from operations, capacity under our credit facility and, when necessary, access to capital markets. In 2026, liquidity is expected to be positively impacted by the proceeds from the sales of NuScale shares and the fabrication yard in China. We have committed and uncommitted lines of credit available for revolving loans and letters of credit. We believe that for at least the next 12 months, anticipated cash generated from operations, along with our unused credit capacity and cash position, is sufficient to support operating requirements and debt maturities. We regularly review our sources and uses of liquidity and may pursue opportunities to address our liquidity needs.

Our credit facility contains provisions that will require us to provide collateral to secure the facility should we be downgraded to BB by S&P and Ba2 by Moody's, which is a one notch downgrade from both agencies' current ratings. If we were required to provide collateral, it would consist broadly of liens on our U.S. assets.

As of December 31, 2025, letters of credit totaling $424 million were outstanding under our $2.2 billion credit facility, which matures in February 2028. This credit facility contains customary financial covenants, including a debt-to-capitalization ratio that cannot exceed 0.60 to 1.00, based upon total shareholders' equity excluding AOCI, a limitation on the aggregate amount of debt of the greater of $750 million or €750 million for our subsidiaries, and a minimum liquidity threshold of $1.1 billion, all as defined in the amended credit facility, which may be reduced to $1.0 billion upon the repayment of debt. Borrowings under the facility, which may be denominated in USD, EUR or GBP, bear interest at a base rate, plus an applicable borrowing margin. As of December 31, 2025 and through the issuance of this 10-K, we had not made any borrowings under our credit line. We have a sub-limit of up to $1.0 billion in aggregate cash advances and financial letters of credit available to us under our credit facility with a current borrowing capacity of $901 million.

Cash and cash equivalents combined with marketable securities were $2.2 billion and $3.0 billion as of December 31, 2025 and 2024, respectively. Cash and cash equivalents are held in numerous accounts throughout the world to fund our global project execution activities. Non-U.S. cash and cash equivalents amounted to $820 million and $1.1 billion as of December 31, 2025 and 2024. Non-U.S. cash and cash equivalents exclude deposits of U.S. legal entities that are invested in offshore, overnight accounts or short-term time deposits, to which there is unrestricted access.

Cash and cash equivalents held by our consolidated variable interest entities (which totaled $328 million and $333 million as of December 31, 2025 and 2024, respectively) were not necessarily readily available for general purposes. We do not include our share of cash held by our proportionately consolidated joint ventures and partnerships in our consolidated cash balances even though these amounts may be significant. We also consider the extent to which client advances (which totaled $14 million and $79 million as of December 31, 2025 and 2024, respectively) are likely to be sustained or consumed over the near term for project execution activities and the cash flow requirements of our various foreign operations. In some cases, it may not be financially efficient to move cash and cash equivalents between countries due to statutory dividend limitations and/or adverse tax consequences. We did not consider any cash to be permanently reinvested outside the U.S. as of December 31, 2025 and 2024, other than unremitted earnings required to meet our working capital and long-term investment needs in non-U.S. foreign jurisdictions where we operate.

In 2025, we sold 15 million of our NuScale shares for net proceeds of $605 million. In February 2026, we completed the sale of 71 million shares of NuScale via a variable price forward sale agreement, generating total proceeds of $1.35 billion. We expect to monetize the remaining 40 million shares of NuScale using similar structured programs and expect that all remaining ownership in NuScale should be sold by the second quarter of 2026.

During 2025, we used $754 million to repurchase and cancel 18 million shares of common stock under our repurchase program. Over 10 million shares could still be purchased under the repurchase program as of December 31, 2025, but in February 2026 our board authorized a 30 million share expansion to the repurchase program. We are targeting approximately $1.4 billion in share repurchases in 2026, including $500 million in the first quarter.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
| **(in millions)** | **2025** | **2024** | **2023** |
| **OPERATING CASH FLOW**<sup>(1)</sup> | $(387) | $828 | $212 |
| **INVESTING CASH FLOW** |  |  |  |
| Proceeds from the sale of NuScale shares | 605 |  |  |
| Proceeds from sales and maturities (purchases) of marketable securities | 75 | (60) | (141) |
| Capital expenditures | (50) | (164) | (106) |
| NuScale cash deconsolidated |  | (131) |  |
| Proceeds from sales of assets (net of cash divested) | 63 | 82 | (5) |
| Investments in partnerships and joint ventures | (278) | (93) | (33) |
| Return of capital from partnerships and joint ventures | 22 | 34 | 8 |
| Other |  | (1) |  |
| Investing cash flow | 437 | (333) | (277) |
| **FINANCING CASH FLOW** |  |  |  |
| Repurchase of common stock | (754) | (125) |  |
| Proceeds from issuance of 2029 Notes, net of issuance costs |  |  | 560 |
| Capped call transactions related to 2029 Notes |  |  | (73) |
| Purchases and retirement of debt | (37) | (57) | (249) |
| Proceeds from NuScale share issuance (net of issuance fees) |  | 80 |  |
| Dividends paid on CPS |  |  | (29) |
| Make-whole payment on conversion of CPS |  |  | (27) |
| Distributions paid to NCI | (64) | (14) | (53) |
| Capital contributions by NCI | 65 |  | 10 |
| Other | (7) |  | (12) |
| Financing cash flow | (797) | (116) | 127 |
| Effect of exchange rate changes on cash | 53 | (69) | 18 |
| Increase (decrease) in cash and cash equivalents | (694) | 310 | 80 |
| Cash and cash equivalents at beginning of year | 2829 | 2519 | 2439 |
| Cash and cash equivalents at end of year | $2135 | $2829 | $2519 |

---

(1) Operating cash flow in 2025 included a payment of $642 million to Santos, net of insurance recoveries, for a judgment related to a reimbursable project completed by us in 2015.

*Operating Activities*

Cash flows from operating activities result primarily from our core EPC activities and are affected by our earnings level and changes in working capital associated with such activities. Working capital levels vary from period to period and are primarily affected by our volume of work and billing schedules on our projects. These levels are also impacted by the stage of completion and commercial terms of engineering and construction projects, as well as our execution of our projects compared to their budget. Working capital requirements also vary by project as well as the payments terms agreed to with our clients, vendors and subcontractors. Most contracts require payments as the projects progress. Additionally, certain projects receive advance payments from clients. A typical trend for our lump-sum projects is to have higher cash balances during the initial phases of execution due to deposits paid to us which then diminish toward the end of the construction phase. As a result, our cash position is reduced as customer advances are utilized, unless they are replaced by advances on other projects. We maintain cash reserves and borrowing facilities to provide additional working capital in the event that a project's net operating cash outflows exceed its available cash balances. As of December 31, 2025, our backlog included $255 million for ongoing legacy projects in a loss position, including approximately $212 million of estimated unfunded losses associated therewith. The comparable amounts in 2024 were $702 million of backlog and $237 million of unfunded losses.

Our operating cash flow for 2025 was significantly impacted by $642 million paid to Santos, net of insurance recoveries, upon a judgment over Santos' efforts to recover costs related to a reimbursable project completed by us in 2015. This decline was partially offset by decreases in working capital on several large projects as well as distributions from a large Energy Solutions joint venture. During 2025, we funded $74 million on 2 consolidated infrastructure projects.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

*Investing Activities*

During 2025, we converted all 126 million of our NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares. We sold 15 million of those shares for net proceeds of $605 million during 2025. In February 2026, we completed the sale of 71 million shares for proceeds of $1.35 billion.

We hold cash in bank deposits and marketable securities which are governed by our investment policy. This policy focuses on, in order of priority, the preservation of capital, maintenance of liquidity and maximization of yield. These investments may include money market funds, bank deposits placed with highly-rated financial institutions, repurchase agreements that are fully collateralized by U.S. Government-related securities, high-grade commercial paper and high quality short-term and medium-term fixed income securities.

Capital expenditures in 2025 primarily related to investments in IT compared to expenditures for improvements to our new office lease in Houston in 2024.

Net proceeds from sales of assets during 2025 included $61 million from the sale of Stork's U.K. operations compared to $67 million from the sale of Stork's European business in 2024.

Investments in partnerships and joint ventures in 2025 included $158 million in funding on a proportionately consolidated loss project for an infrastructure joint venture, $38 million in funding on an Energy Solutions joint venture and $33 million in funding to a separate infrastructure joint venture to make a legal settlement payment. Investments in partnerships and joint ventures in 2024 included capital contributions to an infrastructure joint venture, an Energy Solutions joint venture and a Mission Solutions joint venture.

Return of capital from partnerships and joint ventures in 2024 included capital distribution from an infrastructure joint venture.

In December 2025, we reached an agreement to sell our ownership in the fabrication yard in China for approximately $122 million. The sale is expected to close in 2026, subject to the conditions in the agreement.

*Financing Activities*

We have an ongoing stock repurchase program, authorized by our Board of Directors, to purchase shares in the open market or privately negotiated transactions at our discretion. During 2025, we repurchased 18 million shares of common stock under the repurchase program for total consideration of $754 million. As of December 31, 2025, over 10 million shares could still be purchased under the repurchase program which was expanded by 30 million shares by our board in February 2026.

Key provisions of our debt and debt-related matters are described in the notes to the financial statements. During 2025 and 2024, we redeemed $37 million and $57 million, respectively, of aggregate outstanding 2028 Notes, with an immaterial impact on earnings in both years. During 2023, we redeemed the remaining €129 million of outstanding 2023 Notes for $140 million and completed a tender offer in which we repurchased $115 million of outstanding 2024 Notes, excluding accrued interest, for consideration of $975.03 per $1,000 principal amount of the notes.

In August 2023, we issued our 1.125% Convertible Senior Notes (the "2029 Notes"). The conversion rate for the 2029 Notes is 22.0420 shares of common stock per $1,000 principal amount of notes, which is equivalent to an initial conversion price of $45.37 per share. Holders may convert their 2029 Notes any time before May 2029 under the following conditions:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• if the last reported price of our common stock for at least 20 trading days (whether or not consecutive) during a period of 30 consecutive trading days ending on, and including, the last trading day of the immediately preceding calendar quarter is greater than or equal to $58.98 on each applicable trading day;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• during the 5-business day period after any 5-consecutive trading day period in which the trading price of the 2029 Notes was less than 98% of the product of the last reported stock price and the conversion rate;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• if we call any or all of the 2029 Notes for redemption; or

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• upon the occurrence of specified events as described in the applicable indenture.

In addition, holders may convert their 2029 Notes any time beginning in May 2029 and prior to maturity without regard to the foregoing circumstances. Upon any conversion, we will repay the principal amount of the notes in cash and may elect to convey the conversion premium in any combination of cash and shares of our common stock. Certain events could cause the conversion rate to increase, including a make-whole fundamental change or redemption, but in no event will the conversion rate for a single note exceed 29.2056 shares of our common stock, other than for customary adjustments described in the applicable indenture.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

After August 2026, we may elect to redeem up to all of the outstanding 2029 Notes if our common stock has a prevailing per share closing price in excess of $58.98. In such election, all principal would be settled in cash and could result in a make-whole premium if the holders also elect to convert. We may elect to pay any make-whole premium in any combination of cash and shares of our common stock.

In connection with the 2029 Notes offering, we entered into capped call transactions with certain banks. The strike price of the capped call options corresponds to the conversion price of the 2029 Notes of $45.37 per share. The capped call options are expected to offset potential dilution to our common stock upon conversion of any 2029 Notes and/or offset any cash payments we are required to make for any conversion premium if our stock price is greater than $45.37. The upper limit of the capped calls is $68.48 per share. If our stock price exceeds $68.48, there would be unmitigated dilution and/or no offset of any cash payments attributable to the amount by which our stock exceeds the cap price. We will not be required to make any cash payments to option counterparties upon the exercise of capped call options, but we will be entitled to receive from them shares of our common stock or an amount of cash based on the amount by which the market price of our common stock exceeds the strike price of the capped calls.

Distributions paid to holders of NCI represent cash outflows to partners of consolidated partnerships or joint ventures created primarily for the execution of single contracts or projects. Distributions in 2025 related to 2 consolidated infrastructure projects and a Mission Solutions joint venture. Distributions in 2024 related to the same Mission Solutions joint venture.

During 2024, prior to its deconsolidation, NuScale received $80 million in proceeds from the issuance of their common stock.

*Letters of Credit*

As of December 31, 2025, letters of credit totaling $424 million were outstanding under committed lines of credit. As of December 31, 2025, letters of credit totaling $918 million were outstanding under uncommitted lines of credit including letters of credit totaling $347 million for two lump-sum projects in Kuwait that are substantially complete except for the resolution of unapproved change orders and extension of time claims. Letters of credit are ordinarily provided to indemnify our clients if we fail to perform our obligations under our contracts. Surety bonds may be used as an alternative to letters of credit.

*Guarantees*

The maximum potential amount of future payments that we could be required to make under outstanding performance guarantees, which represents the remaining cost of work to be performed, was estimated to be $14 billion as of December 31, 2025.

Financial guarantees, made in the ordinary course of business in certain limited circumstances, are entered into with financial institutions and other credit grantors and generally obligate us to make payment in the event of a default by the borrower. These arrangements generally require the borrower to pledge collateral to support the fulfillment of the borrower's obligation.

**Item 7A.&nbsp;&nbsp;&nbsp;&nbsp;*Quantitative and Qualitative Disclosures about Market Risk***

We have cash and marketable securities on deposit with major banks throughout the world. Such deposits are placed with high quality institutions and the amounts invested in any single institution are limited to the extent possible in order to minimize concentration of counterparty credit risk. Marketable securities may consist of time deposits, registered money market funds, U.S. agency securities, U.S. Treasury securities, commercial paper, non-U.S. government securities and corporate debt securities. We have not incurred any credit risk losses related to deposits in cash or investments in marketable securities.

Certain of our contracts are subject to foreign currency risk. We limit exposure to foreign currency fluctuations in most of our contracts through provisions that specify client payments in currencies corresponding to the currency in which cost is expected to be incurred. As a result, we generally have limited situations in which we have to mitigate foreign currency exposure with derivatives.

Our results reported by foreign subsidiaries with non-U.S. dollar functional currencies are also affected by foreign currency volatility. When the U.S. dollar appreciates against the non-U.S. dollar functional currencies of these subsidiaries, our reported revenue, cost and earnings, after translation into U.S. dollars, are lower than what they would have been had the U.S. dollar depreciated against the same foreign currencies or if there had been no change in the exchange rates.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Our long-term debt typically features a fixed-rate coupon. The fees we pay on our outstanding letters of credit are also fixed rates based on our credit ratings. Therefore, our exposure to floating interest rates is not material to interest expense. However, in the future, any new debt issuances could be exposed to increasing interest rates or feature floating interest rates.

**Item 8.&nbsp;&nbsp;&nbsp;&nbsp;*Financial Statements and Supplementary Data***

The information required by this Item is submitted as a separate section of this Form 10-K as described in Item 15.

**Item 9.&nbsp;&nbsp;&nbsp;&nbsp;*Changes in and Disagreements with Accountants on Accounting and Financial Disclosure***

None.

**Item 9A.&nbsp;&nbsp;&nbsp;&nbsp;Controls and Procedures** 

***Evaluation of Disclosure Controls and Procedures***

As defined in Rule 13a-15 and 15d-15 of the Exchange Act, our management, with the participation of our CEO and CFO, is responsible for establishing and maintaining disclosure controls and procedures. These controls and procedures should be designed to provide reasonable assurance that information required to be disclosed by us in reports we file or submit under the Exchange Act is recorded, processed, summarized and reported within the time periods specified in the rules and forms of the SEC, and that the information required to be disclosed by us in reports that we file or submit under the Exchange Act is accumulated and communicated to our management, including the CEO and CFO, to allow timely decisions regarding required disclosure.

Based on their evaluation, our CEO and CFO have concluded that our disclosure controls and procedures were effective as of December 31, 2025.

***Management's Report on Internal Control over Financial Reporting***

Our management is responsible for establishing and maintaining adequate ICFR that is designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements in accordance with GAAP.

Our management, including our CEO and CFO, conducted an assessment of the effectiveness of our ICFR as of December 31, 2025 based upon the framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (COSO 2013) and concluded that our ICFR was effective.

Ernst & Young LLP, our independent registered public accounting firm, has issued an attestation report on the effectiveness of our ICFR. Their report follows this management report.

***Changes in Internal Control over Financial Reporting***

There have been no changes in our ICFR during the fourth quarter of 2025 that have materially affected, or are reasonably likely to materially affect, our ICFR.

**Report of Independent Registered Public Accounting Firm**

To the Shareholders and the Board of Directors of Fluor Corporation

**Opinion on Internal Control Over Financial Reporting**

We have audited Fluor Corporation's internal control over financial reporting as of December 31, 2025, based on criteria established in Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (2013 framework) (the COSO criteria). In our opinion, Fluor Corporation (the Company) maintained, in all material respects, effective internal control over financial reporting as of December 31, 2025, based on the COSO criteria.

We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States) (PCAOB), the consolidated balance sheets of the Company as of December 31, 2025 and 2024, the related consolidated statements of operations, comprehensive income, changes in equity and cash flows for each of the three years in the period ended December 31, 2025, and the related notes and our report dated February 17, 2026 expressed an unqualified opinion thereon.

**Basis for Opinion**

The Company's management is responsible for maintaining effective internal control over financial reporting and for its assessment of the effectiveness of internal control over financial reporting included in the accompanying Management's

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Report on Internal Control over Financial Reporting. Our responsibility is to express an opinion on the Company's internal control over financial reporting based on our audit. We are a public accounting firm registered with the PCAOB and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audit in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether effective internal control over financial reporting was maintained in all material respects.

Our audit included obtaining an understanding of internal control over financial reporting, assessing the risk that a material weakness exists, testing and evaluating the design and operating effectiveness of internal control based on the assessed risk, and performing such other procedures as we considered necessary in the circumstances. We believe that our audit provides a reasonable basis for our opinion.

**Definition and Limitations of Internal Control Over Financial Reporting**

A company's internal control over financial reporting is a process designed to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles. A company's internal control over financial reporting includes those policies and procedures that (1) pertain to the maintenance of records that, in reasonable detail, accurately and fairly reflect the transactions and dispositions of the assets of the company; (2) provide reasonable assurance that transactions are recorded as necessary to permit preparation of financial statements in accordance with generally accepted accounting principles, and that receipts and expenditures of the company are being made only in accordance with authorizations of management and directors of the company; and (3) provide reasonable assurance regarding prevention or timely detection of unauthorized acquisition, use, or disposition of the company's assets that could have a material effect on the financial statements.

Because of its inherent limitations, internal control over financial reporting may not prevent or detect misstatements. Also, projections of any evaluation of effectiveness to future periods are subject to the risk that controls may become inadequate because of changes in conditions, or that the degree of compliance with the policies or procedures may deteriorate.

/s/ Ernst & Young LLP

Dallas, Texas

February 17, 2026

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Item 9B.&nbsp;&nbsp;&nbsp;&nbsp;*Other Information***

**Rule 10b5-1 Trading Plans**

During the quarter ended December 31, 2025, the following individuals adopted or terminated Rule 10b5-1 trading arrangements (as defined in Item 408(a) of Regulation S-K) intended to satisfy the affirmative defense conditions of Rule 10b5-1(c) of the Exchange Act:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• On December 4, 2025, Alvin C. Collins III, Business Group President, Mission Solutions, adopted a 10b5-1 trading arrangement providing for the sale of up to 15,712 shares of common stock and the exercise of up to 5,712 stock options (including the sale of the underlying shares of common stock), subject to certain conditions, which will terminate on March 10, 2027.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• On December 4, 2025, Anthony Morgan, Business Group President, Urban Solutions, terminated a 10b5-1 trading arrangement previously adopted on August 7, 2025. The terminated plan provided for the sale of up to 8,500 shares of common stock and the exercise of up to 6,813 stock options (including the sale of the underlying shares of common stock), subject to certain conditions.

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• On December 5, 2025, Anthony Morgan, Business Group President, Urban Solutions, adopted a 10b5-1 trading arrangement providing for the sale of up to 8,500 shares of common stock and the exercise of up to 3,426 stock options (including the sale of the underlying shares of common stock), subject to certain conditions, which will terminate on February 23, 2027.

**Item 9C.&nbsp;&nbsp;&nbsp;&nbsp;*Disclosure Regarding Foreign Jurisdictions that Prevent Inspections***

Not Applicable.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**PART III**

**Item 10.&nbsp;&nbsp;&nbsp;&nbsp;*Directors, Executive Officers and Corporate Governance***

**Directors, Executive Officers, Promoters and Control Persons**

Except as provided below, the information required by this item will be included in our definitive proxy statement to be filed with the SEC pursuant to Regulation 14A within 120 days after the close of our fiscal year (our "Proxy Statement") and is incorporated herein by reference. The information required by Paragraph (b) of Item 401 of Regulation S-K, as well as the information required by Paragraphs (d) — (f) of that Item to the extent the required information pertains to our executive officers, is set forth herein at Part I, Item 1 of this 2025 10-K under the heading "Information about our Executive Officers."

**Code of Ethics** 

We have long maintained and enforced a *Code of Business Conduct and Ethics* that applies to all employees, including our CEO, CFO and CAO. A copy of our *Code of Business Conduct and Ethics*, as amended, has been posted on the "Compliance and Ethics" portion of our website *(www.fluor.com)*.

We intend to continue to disclose any changes or amendments to our code of ethics or waivers from our code of ethics applicable to our CEO, CFO and CAO by posting such changes or waivers to our website within 4 business days of any amendment or waiver.

**Insider Trading Policy**

We have adopted an insider trading policy governing the purchase, sale, and/or other dispositions of our securities by our directors, officers, employees and contractors that we believe is reasonably designed to promote compliance with insider trading laws, rules and regulations, and applicable exchange listing standards. We also comply with all applicable laws (including appropriate approvals by the Board of Directors or appropriate committee if required) when engaging in transactions in our own securities. A copy of our insider trading policy is filed as Exhibit 19.1 to this 2025 10-K.

**Corporate Governance**

We have adopted corporate governance guidelines, which are available under "Governance" on our website *(www.fluor.com)*.

**Item 11.&nbsp;&nbsp;&nbsp;&nbsp;*Executive Compensation***

Information required by this item will be included in our Proxy Statement, which information is incorporated herein by reference.

**Item 12.&nbsp;&nbsp;&nbsp;&nbsp;*Security Ownership of Certain Beneficial Owners and Management and Related Stockholder Matters***

**Equity Compensation Plan Information**

The following table provides information as of December 31, 2025 with respect to the shares of common stock that may be issued under our equity compensation plans:

---

| | | | |
|:---|:---|:---|:---|
| Plan Category | **(a)<br>Number of securities to be<br>issued upon exercise of<br>outstanding options,<br>warrants and rights** | **(b)<br>Weighted average<br>exercise price of<br>outstanding options,<br>warrants and rights** | **(c)<br>Number of securities available for<br>future issuance under equity<br>compensation plans (excluding<br>securities listed in column (a))** |
| Equity compensation plans approved by stockholders<sup>(1)</sup> | 4737798 | $34.48<sup>(3)</sup> | 6421510 |
| Equity compensation plans not approved by stockholders<sup>(2)</sup> | 283281 | $17.20<sup>(3)</sup> |  |
| Total | 5021079 |  | 6421510 |

---

_______________________________________________________________________________

(1)Consists of (a) the Amended and Restated 2008 Executive Performance Incentive Plan, under which 1,039,546 shares are issuable upon exercise of outstanding options, and under which no shares remain for future issuance; (b) the 2017 Performance Incentive Plan, under which 751,021 shares are issuable upon exercise of outstanding options, and under which no shares remain available for issuance; (c) the 2020 Performance Incentive Plan, under which 1,155,323 shares are issuable upon exercise of outstanding options, 941,903 shares are issuable upon vesting of outstanding RSUs, 780,972

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

shares are issuable if specified performance targets are met under outstanding performance-based award units, and under which 6,421,510 remain available for issuance; and (d) 4,989, 15,450 and 48,594 vested RSUs under the 2008 Executive Performance Plan, 2017 Performance Incentive Plan and 2020 Performance Incentive Plan, respectively, that were deferred by non-associate directors participating in the 409A Director Deferred Compensation Program that are distributable in the form of shares.

(2)Consists of inducement awards made to Mr. David E. Constable in connection with his appointment as CEO in 2021.

(3)Weighted-average exercise price of outstanding options only.

The additional information required by this item will be included in our Proxy Statement, which information is incorporated by reference.

**Item 13.&nbsp;&nbsp;&nbsp;&nbsp;*Certain Relationships and Related Transactions, and Director Independence***

Information required by this item will be included in our Proxy Statement, which information is incorporated herein by reference.

**Item 14.&nbsp;&nbsp;&nbsp;&nbsp;*Principal Accountant Fees and Services***

Information required by this item will be included in our Proxy Statement, which information is incorporated herein by reference.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**PART IV**

**Item 15.&nbsp;&nbsp;&nbsp;&nbsp;*Exhibits and Financial Statement Schedules***

(a)Documents filed as part of this 2025 10-K:

1.*Financial Statements:*

Our consolidated financial statements at December 31, 2025 and 2024 and for each of the 3 years in the period ended December 31, 2025, together with the report of our independent registered public accounting firm on those consolidated financial statements are hereby filed as part of this 2025 10-K, beginning on page F-1.

2.*Financial Statement Schedules:*

No financial statement schedules are presented since the required information is not present or not present in amounts sufficient to require submission of the schedule, or because the information required is included in the consolidated financial statements and notes thereto.

3.*Exhibits:*

NuScale is a significant equity method investment, and therefore, separate audited financial statements for NuScale are required to be included in the 2025 10-K. We intend to file a Form 10-K/A to include NuScale's audited financial statements for the year ended December 31, 2025.

---

| | |
|:---|:---|
| **Exhibit** | **Description** |
| 3.1 | <u>[Amended and Restated Certificate of Incorporation of the registrant (incorporated by reference to Exhibit 3.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on May 8, 2012).](https://www.sec.gov/Archives/edgar/data/1124198/000110465912034497/a12-11553_1ex3d1.htm)</u> |
| 3.2 | <u>[Amended and Restated Bylaws of the registrant (incorporated by reference to Exhibit 3.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on November 4, 2022).](https://www.sec.gov/Archives/edgar/data/1124198/000162828022028338/exhibit3_1.htm)</u> |
| 4.1 | <u>[Senior Debt Securities Indenture between Fluor Corporation and Wells Fargo Bank, National Association, as trustee, dated as of September 8, 2011 (incorporated by reference to Exhibit 4.3 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on September 8, 2011).](https://www.sec.gov/Archives/edgar/data/1124198/000110465911050707/a11-24717_1ex4d3.htm)</u> |
| 4.2 | <u>[First Supplemental Indenture between Fluor Corporation and Wells Fargo Bank, National Association, as trustee, dated as of September 13, 2011 (incorporated by reference to Exhibit 4.4 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on September 13, 2011).](https://www.sec.gov/Archives/edgar/data/1124198/000110465911051457/a11-26357_1ex4d4.htm)</u> |
| 4.3 | <u>[Second Supplemental Indenture between Fluor Corporation and Wells Fargo Bank, National Association, as trustee, dated as of June 22, 2012 (incorporated by reference to Exhibit 4.2 to the registrant's Registration Statement on Form S-3 (Commission file number 333-182283) filed on June 22, 2012).](https://www.sec.gov/Archives/edgar/data/1124198/000104746912006861/a2210003zex-4_2.htm)</u> |
| 4.4 | <u>[Third Supplemental Indenture between Fluor Corporation and Wells Fargo Bank, National Association, as trustee, dated as of November 25, 2014 (incorporated by reference to Exhibit 4.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on November 25, 2014).](https://www.sec.gov/Archives/edgar/data/1124198/000110465914083151/a14-25083_1ex4d1.htm)</u> |
| 4.5 | <u>[Fourth Supplemental Indenture between Fluor Corporation and Wells Fargo Bank, National Association, as trustee, dated as of March 21, 2016 (incorporated by reference to Exhibit 4.3 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on March 21, 2016).](https://www.sec.gov/Archives/edgar/data/1124198/000110465916106604/a16-5135_5ex4d3.htm)</u> |
| 4.6 | <u>[Fifth Supplemental Indenture between Fluor Corporation and Wells Fargo Bank, National Association, as trustee, dated as of August 29, 2018 (incorporated by reference to Exhibit 4.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on August 29, 2018).](https://www.sec.gov/Archives/edgar/data/1124198/000110465918054168/a18-22016_1ex4d1.htm)</u> |
| 4.7 | <u>[Indenture, dated August 10, 2023, between Fluor Corporation and U.S. Bank Trust Company, National Association, as trustee (incorporated by reference to Exhibit 4.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on August 11, 2023)](https://www.sec.gov/Archives/edgar/data/1124198/000110465923090465/tm2323493d1_ex4-1.htm)</u>. |
| 4.8 | <u>[Form of 1.125% Convertible Senior Note due 2029 (included in Exhibit 4.7).](https://www.sec.gov/Archives/edgar/data/1124198/000110465923090465/tm2323493d1_ex4-1.htm)</u> |
| 4.9 | <u>[Description of Securities (incorporated by reference to Exhibit 4.7 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 21, 2023).](https://www.sec.gov/Archives/edgar/data/1124198/000162828023004139/ex47descriptionofsecuritie.htm)</u> |
| 10.1 | <u>[Fluor Corporation Amended and Restated 2008 Executive Performance Incentive Plan (incorporated by reference to Exhibit 10.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on May 3, 2013).](https://www.sec.gov/Archives/edgar/data/1124198/000110465913036983/a13-11469_1ex10d1.htm)</u>\*\* |
| 10.2 | <u>[Form of Option Agreement (2017 grants) under the Fluor Corporation Amended and Restated 2008 Executive Performance Incentive Plan (incorporated by reference to Exhibit 10.6 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 17, 2017).](https://www.sec.gov/Archives/edgar/data/1124198/000104746917000724/a2230876zex-10_6.htm)</u>\*\* |
| 10.3 | <u>[Fluor Corporation 2017 Performance Incentive Plan (incorporated by reference to Exhibit 10.1 to the registrant's Registration Statement on Form S-8 (Commission file number 333-217653) filed on May 4, 2017).](https://www.sec.gov/Archives/edgar/data/1124198/000110465917029772/a17-12066_1ex10d1.htm)</u>\*\* |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

---

| | |
|:---|:---|
| **Exhibit** | **Description** |
| 10.4 | <u>[Form of Option Agreement under the Fluor Corporation 2017 Performance Incentive Plan (incorporated by reference to Exhibit 10.16 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on May 3, 2018).](https://www.sec.gov/Archives/edgar/data/1124198/000110465918030273/a18-8612_1ex10d16.htm)</u>\*\* |
| 10.5 | <u>[Form of Option Agreement (2020 grant) under the Fluor Corporation 2017 Performance Incentive Plan (incorporated by reference to Exhibit 10.2 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on December 10, 2020).](https://www.sec.gov/Archives/edgar/data/1124198/000162828020017321/flr2020q3ex102.htm)</u>\*\* |
| 10.6 | <u>[Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 99.1 to the registrant's Registration Statement on Form S-8 (Commission file number 333-251426) filed on December 17, 2020.](https://www.sec.gov/Archives/edgar/data/1124198/000110465920136907/tm2038607d1_ex99-1.htm)</u>\*\* |
| 10.7 | <u>[Form of Option Agreement (2021 grant) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.17 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 22, 2022).](https://www.sec.gov/Archives/edgar/data/1124198/000162828022003231/ex1017formofoptionagreement.htm)</u>\*\* |
| 10.8 | <u>[Form of Option Agreement (2022 grant) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.2 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on May 6, 2022).](https://www.sec.gov/Archives/edgar/data/1124198/000162828022012833/flr2022q1ex102.htm)</u>\*\* |
| 10.9 | <u>[Form of Option Agreement (2023 grant) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.1 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 5. 2023).](https://www.sec.gov/Archives/edgar/data/1124198/000162828023015984/flr2023q1ex101.htm)</u>\*\* |
| 10.10 | <u>[Form of Option Agreement (2024 grant) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.1 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 3. 2024).](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex101.htm)</u>\*\* |
| 10.11 | <u>[Form of Restricted Stock Unit Agreement (2023 grant) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.2 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 5. 2023).](https://www.sec.gov/Archives/edgar/data/1124198/000162828023015984/flr2023q1ex102.htm)</u>\*\* |
| 10.12 | <u>[Form of Restricted Stock Unit Agreement (2024](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex102.htm)[and 2025](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex102.htm)[grant](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex102.htm)[s](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex102.htm)[) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.2 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 3. 2024).](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex102.htm)</u>\*\* |
| 10.13 | <u>[Form of Performance Award (2023 grant) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.3 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 5. 2023).](https://www.sec.gov/Archives/edgar/data/1124198/000162828023015984/flr2023q1ex103.htm)</u>\*\* |
| 10.14 | <u>[Form of Performance Award (2024](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex103.htm)[and 2025](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex103.htm)[grant](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex103.htm)[s](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex103.htm)[) under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.3 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 3. 2024).](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex103.htm)</u>\*\* |
| 10.15 | <u>[Form of Stock Growth Incentive Agreement under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.4 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16120) filed on May 3. 2024).](https://www.sec.gov/Archives/edgar/data/1124198/000162828024020092/flr2024q1ex104.htm)</u>\*\* |
| 10.16 | <u>[Fluor Executive Deferred Compensation Plan, as amended and restated effective April 21, 2003 (incorporated by reference to Exhibit 10.5 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 29, 2008).](https://www.sec.gov/Archives/edgar/data/1124198/000104746908002025/a2182997zex-10_5.htm)</u>\*\* |
| 10.17 | <u>[Fluor 409A Executive Deferred Compensation Program, as amended and restated effective January 1, 2017 (incorporated by reference to Exhibit 10.16 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on November 2, 2017).](https://www.sec.gov/Archives/edgar/data/1124198/000110465917065675/a17-20578_1ex10d16.htm)</u>\*\* |
| 10.18 | <u>[Executive Severance Plan (incorporated by reference to Exhibit 10.7 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 22, 2012).](https://www.sec.gov/Archives/edgar/data/1124198/000104746912001294/a2207387zex-10_7.htm)</u>\*\* |
| 10.19 | <u>[Offer Letter, dated October 30, 2020, between the registrant and David E. Constable (incorporated by reference to Exhibit 10.26 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 26, 2021).](https://www.sec.gov/Archives/edgar/data/1124198/000162828021003360/ex10_26constableofferletter.htm)</u>\*\* |
| 10.20 | <u>[Option Agreement, dated December 23, 2020, between the registrant and David E. Constable (incorporated by reference to Exhibit 10.27 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 26, 2021).](https://www.sec.gov/Archives/edgar/data/1124198/000162828021003360/ex10_27constableoptionagre.htm)</u>\*\* |
| 10.21 | <u>[Restricted Stock Unit Agreement, dated December 23, 2020, between the registrant and David E. Constable (incorporated by reference to Exhibit 10.28 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 26, 2021).](https://www.sec.gov/Archives/edgar/data/1124198/000162828021003360/ex10_28constablersuagreeme.htm)</u>\*\* |
| 10.22 | <u>[Letter Agreement, effective as of J](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[uly 2, 2025, between Fluor Corporation and James R. Breuer (incorporated by reference to Exhibit 10.1 to the registrant's Quarterly Report on Form](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[1](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[0-](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[Q](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[(Commission file number 1-16129) filed on Novemb](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[er](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[7,](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)[2025).](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex101.htm)</u>\*\* |
| 10.23 | <u>[Consulting Agreement, dated as of June 19, 2025, between FDEE Consulting, Inc. and John](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000027/flr2025q2ex101.htm)[R.](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000027/flr2025q2ex101.htm)[Reynolds (incorporated by reference to Exhibit 10.1 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on August 1, 2025)](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000027/flr2025q2ex101.htm)</u>.\*\* |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

---

| | |
|:---|:---|
| **Exhibit** | **Description** |
| 10.24 | <u>[Consulting Agreement, effective as of J](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex102.htm)[uly 2, 2025, between FDEE Consulting, Inc. and Joseph L. Brennan](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex102.htm)[(incorporated by reference to Exhibit 10.2 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on November 7, 2025).](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000073/flr2025q3ex102.htm)</u>\*\* |
| 10.25 | <u>[Summary of Fluor Corporation Non-Management Director Compensation](flr2025q4ex1025.htm)[.](flr2025q4ex1025.htm)</u>\* \*\* |
| 10.26 | <u>[Form of Restricted Stock Unit Agreement granted to directors under the Fluor Corporation 2020 Performance Incentive Plan (incorporated by reference to Exhibit 10.32 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 26, 2021).](https://www.sec.gov/Archives/edgar/data/1124198/000162828021003360/ex10_32directorrsu.htm)</u>\*\* |
| 10.27 | <u>[Fluor Corporation Deferred Directors' Fees Program, as amended and restated effective January 1, 2002 (incorporated by reference to Exhibit 10.9 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on March 31, 2003).](https://www.sec.gov/Archives/edgar/data/1124198/000089256903000847/a88362exv10w9.txt)</u>\*\* |
| 10.28 | <u>[Fluor Corporation 409A Director Deferred Compensation Program, as amended and restated effective as of November 2, 2016 (incorporated by reference to Exhibit 10.22 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 17, 2017).](https://www.sec.gov/Archives/edgar/data/1124198/000104746917000724/a2230876zex-10_22.htm)</u>\*\* |
| 10.29 | <u>[Directors' Life Insurance Summary (incorporated by reference to Exhibit 10.12 to the registrant's Registration Statement on Form 10/A (Amendment No. 1) (Commission file number 1-16129) filed on November 22, 2000).](https://www.sec.gov/Archives/edgar/data/1124198/000102140800003763/0001021408-00-003763-0016.txt)</u>\*\* |
| 10.30 | <u>[Form of Indemnification Agreement entered into between the registrant and each of its directors and executive officers (incorporated by reference to Exhibit 10.21 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 25, 2009).](https://www.sec.gov/Archives/edgar/data/1124198/000104746909001811/a2190865zex-10_21.htm)</u> |
| 10.31 | <u>[Form of Change in Control Agreement entered into between the registrant and each of its executive officers (incorporated by reference to Exhibit 10.1 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on June 29, 2010).](https://www.sec.gov/Archives/edgar/data/1124198/000110465910036024/a10-13275_1ex10d1.htm)</u>\*\* |
| 10.32 | <u>[$2,200,000 Fourth Amended and Restated Revolving Loan and Letter of Credit Facility Agreement dated as of February 14, 2025, among Fluor Corporation, the Lenders thereunder, BNP Paribas, as Administrative Agent and an Issuing Lender, Bank of America, N.A., as Syndication Agent, and Citibank, N.A. and Wells Fargo Bank, National Association, as Co-Documentation Agents (incorporated by reference to Exhibit 10.1 to the registrant's Quarterly Report on Form 10-Q (Commission file number 1-16129) filed on May](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000007/flr2025q1ex101.htm)[2](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000007/flr2025q1ex101.htm)[, 2025).](https://www.sec.gov/Archives/edgar/data/1124198/000112419825000007/flr2025q1ex101.htm)</u> |
| 10.33 | <u>[Form of Capped Call Confirmation (incorporated by reference to Exhibit 10.2 to the registrant's Current Report on Form 8-K (Commission file number 1-16129) filed on August 11, 2023)](https://www.sec.gov/Archives/edgar/data/1124198/000110465923090465/tm2323493d1_ex10-2.htm)</u>. |
| 19.1 | <u>[Ins](https://www.sec.gov/Archives/edgar/data/1124198/000162828025005924/flr2024q4ex191.htm)[ider Trading Policy](https://www.sec.gov/Archives/edgar/data/1124198/000162828025005924/flr2024q4ex191.htm)[(incorporated by reference to Exhibit 19.1 to the registrant's A](https://www.sec.gov/Archives/edgar/data/1124198/000162828025005924/flr2024q4ex191.htm)[nnual Report](https://www.sec.gov/Archives/edgar/data/1124198/000162828025005924/flr2024q4ex191.htm)[on Form 10-K (Commission file number 1-1612](https://www.sec.gov/Archives/edgar/data/1124198/000162828025005924/flr2024q4ex191.htm)[9) filed on February 18, 2025).](https://www.sec.gov/Archives/edgar/data/1124198/000162828025005924/flr2024q4ex191.htm)</u> |
| 21.1 | <u>[Subsidiaries of the registrant.](flr2025q4ex211.htm)</u>\* |
| 23.1 | <u>[Consent of Independent Registered Public Accounting Firm.](flr2025q4ex231.htm)</u>\* |
| 31.1 | <u>[Certification of Chief Executive Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.\*](flr2025q4ex311.htm)</u> |
| 31.2 | <u>[Certification of Chief Financial Officer pursuant to Section 302 of the Sarbanes-Oxley Act of 2002.\*](flr2025q4ex312.htm)</u> |
| 32.1 | <u>[Certification of Chief Executive Officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.\*](flr2025q4ex321.htm)</u> |
| 32.2 | <u>[Certification of Chief Financial Officer pursuant to Section 906 of the Sarbanes-Oxley Act of 2002.](flr2025q4ex322.htm)</u>\* |
| 95.1 | <u>[Mine Safety Disclosure.\*](flr2025q4ex951.htm)</u> |
| 97.1 | <u>[Compensation Recoupment (Clawback) Policy for Executive Officers (incorporated by reference to Exhibit 97.1 to the registrant's Annual Report on Form 10-K (Commission file number 1-16129) filed on February 20, 2024).](https://www.sec.gov/Archives/edgar/data/1124198/000162828024005451/flr2023q4ex971.htm)[\*\*](https://www.sec.gov/Archives/edgar/data/1124198/000162828024005451/flr2023q4ex971.htm)</u> |
| 101.INS | Inline XBRL Instance Document.\* |
| 101.SCH | Inline XBRL Taxonomy Extension Schema Document.\* |
| 101.CAL | Inline XBRL Taxonomy Extension Calculation Linkbase Document.\* |
| 101.LAB | Inline XBRL Taxonomy Extension Label Linkbase Document.\* |
| 101.PRE | Inline XBRL Taxonomy Extension Presentation Linkbase Document.\* |
| 101.DEF | Inline XBRL Taxonomy Extension Definition Linkbase Document.\* |
| 104 | The cover page from the Company's 2025 10-K for the year ended December 31, 2025, formatted in Inline XBRL (included in the Exhibit 101 attachments).\* |

---

_______________________________________________________________________________

\*&nbsp;&nbsp;&nbsp;&nbsp;Exhibit filed with this report.

\*\*&nbsp;&nbsp;&nbsp;&nbsp;Management contract or compensatory plan or arrangement.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

Attached as Exhibit 101 to this report are the following documents formatted in XBRL (Extensible Business Reporting Language): (i) the Consolidated Statement of Operations for the years ended December 31, 2025, 2024 and 2023, (ii) the Consolidated Balance Sheet at December 31, 2025 and December 31, 2024, (iii) the Consolidated Statement of Cash Flows for the years ended December 31, 2025, 2024 and 2023 and (iv) the Consolidated Statement of Equity for the years ended December 31, 2025, 2024 and 2023.

**Item 16.&nbsp;&nbsp;&nbsp;&nbsp;*Form 10-K Summary***

None.

**SIGNATURES**

Pursuant to the requirements of Section 13 or 15(d) of the Securities Exchange Act of 1934, the registrant has duly caused this 2025 10-K to be signed on its behalf by the undersigned, thereunto duly authorized.

---

| | |
|:---|:---|
| FLUOR CORPORATION | FLUOR CORPORATION |
| By: | /s/ JOHN C. REGAN |
|  | John C. Regan,<br>Chief Financial Officer |

---

February 17, 2026

Pursuant to the requirements of the Securities Exchange Act of 1934, this 2025 10-K has been signed below by the following persons on behalf of the registrant and in the capacities and on the dates indicated.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

---

| | | |
|:---|:---|:---|
| **Signature** | **Title** | **Date** |
| **Principal Executive Officer and Director:** | | |
| /s/ JAMES R. BREUER |  |  |
| James R. Breuer | Chief Executive Officer and Director | February 17, 2026 |
| **Principal Financial Officer:** |  |  |
| /s/ JOHN C. REGAN |  |  |
| John C. Regan | Chief Financial Officer | February 17, 2026 |
| **Principal Accounting Officer:** |  |  |
| /s/ JAMES P. ELLIOTT |  |  |
| James P. Elliott | Chief Accounting Officer | February 17, 2026 |
| **Other Directors:** |  |  |
| /s/ DAVID E. CONSTABLE |  |  |
| David E. Constable | Executive Chairman | February 17, 2026 |
| /s/ ALAN M. BENNETT |  |  |
| Alan M. Bennett | Director | February 17, 2026 |
| /s/ ROSEMARY T. BERKERY |  |  |
| Rosemary T. Berkery | Director | February 17, 2026 |
| /s/ CHARLES BLANKENSHIP |  |  |
| Charles Blankenship | Director | February 17, 2026 |
| /s/ H. PAULETT EBERHART |  |  |
| H. Paulett Eberhart | Director | February 17, 2026 |
| /s/ LISA GLATCH |  |  |
| Lisa Glatch | Director | February 17, 2026 |
| /s/ JAMES T. HACKETT |  |  |
| James T. Hackett | Director | February 17, 2026 |
| /s/ TERI P. MCCLURE |  |  |
| Teri P. McClure | Director | February 17, 2026 |
| /s/ MATTHEW K. ROSE |  |  |
| Matthew K. Rose | Director | February 17, 2026 |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**INDEX TO CONSOLIDATED FINANCIAL STATEMENTS**

---

| | |
|:---|:---|
| **TABLE OF CONTENTS** | **PAGE** |
| Report of Independent Registered Public Accounting Firm (PCAOB ID: 42) | <u>F-[2](#i99155b137c484eadafc407f6a8cc1413_109)</u> |
| Consolidated Statement of Operations | <u>F-[4](#i99155b137c484eadafc407f6a8cc1413_112)</u> |
| Consolidated Statement of Comprehensive Income | <u>F-[5](#i99155b137c484eadafc407f6a8cc1413_115)</u> |
| Consolidated Balance Sheet | <u>F-[6](#i99155b137c484eadafc407f6a8cc1413_118)</u> |
| Consolidated Statement of Cash Flows | <u>F-[7](#i99155b137c484eadafc407f6a8cc1413_124)</u> |
| Consolidated Statement of Changes in Equity | <u>F-[8](#i99155b137c484eadafc407f6a8cc1413_130)</u> |
| Notes to Consolidated Financial Statements | <u>F-[9](#i99155b137c484eadafc407f6a8cc1413_136)</u> |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**Report of Independent Registered Public Accounting Firm** 

To the Shareholders and the Board of Directors of Fluor Corporation

**Opinion on the Financial Statements**

We have audited the accompanying consolidated balance sheets of Fluor Corporation (the Company) as of December 31, 2025 and 2024, the related consolidated statements of operations, comprehensive income, changes in equity and cash flows for each of the three years in the period ended December 31, 2025, and the related notes (collectively referred to as the "consolidated financial statements"). In our opinion, the consolidated financial statements present fairly, in all material respects, the financial position of the Company at December 31, 2025 and 2024, and the results of its operations and its cash flows for each of the three years in the period ended December 31, 2025, in conformity with U.S. generally accepted accounting principles.

We also have audited, in accordance with the standards of the Public Company Accounting Oversight Board (United States) (PCAOB), the Company's internal control over financial reporting as of December 31, 2025, based on criteria established in

Internal Control—Integrated Framework issued by the Committee of Sponsoring Organizations of the Treadway Commission (2013 framework), and our report dated February 17, 2026 expressed an unqualified opinion thereon.

**Basis for Opinion**

These financial statements are the responsibility of the Company's management. Our responsibility is to express an opinion on the Company's financial statements based on our audits. We are a public accounting firm registered with the PCAOB and are required to be independent with respect to the Company in accordance with the U.S. federal securities laws and the applicable rules and regulations of the Securities and Exchange Commission and the PCAOB.

We conducted our audits in accordance with the standards of the PCAOB. Those standards require that we plan and perform the audit to obtain reasonable assurance about whether the financial statements are free of material misstatement, whether due to error or fraud. Our audits included performing procedures to assess the risks of material misstatement of the financial statements, whether due to error or fraud, and performing procedures that respond to those risks. Such procedures included examining, on a test basis, evidence regarding the amounts and disclosures in the financial statements. Our audits also included evaluating the accounting principles used and significant estimates made by management, as well as evaluating the overall presentation of the financial statements. We believe that our audits provide a reasonable basis for our opinion.

**Critical Audit Matter**

The critical audit matter communicated below is a matter arising from the current period audit of the financial statements that was communicated or required to be communicated to the audit committee and that: (1) relates to accounts or disclosures that are material to the financial statements and (2) involved our especially challenging, subjective or complex judgments. The communication of the critical audit matter does not alter in any way our opinion on the consolidated financial statements, taken as a whole, and we are not, by communicating the critical audit matter below, providing a separate opinion on the critical audit matter or on the account or disclosures to which it relates.

---

| | |
|:---|:---|
| | **Revenue recognition on certain engineering and construction contracts** |
| *Description of the Matter* | As described in Note 2 to the consolidated financial statements, the Company recognizes engineering and construction contract revenue over time, as services are provided to satisfy performance obligations, based on the ratio of costs incurred to date compared to total estimated contract cost. Revenue recognition under this method is subject to judgment, as it requires management to prepare estimates of total contract revenue including variable consideration associated with unapproved change orders, customer claims, and incentives, and costs to complete in-process contracts. <br>Management's estimates of total contract revenue and costs on certain engineering and construction contracts is subjective, requiring considerable auditor judgment in evaluating (1) the amount of recognized variable consideration potentially subject to customer claims, backcharges and penalties and (2) forecasted reductions in cost associated with expected subcontractor backcharge recoveries. |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

---

| | |
|:---|:---|
| *How We Addressed the Matter in Our Audit* | We obtained an understanding, evaluated the design, and tested the operating effectiveness of controls over the estimation process that affect revenue recognition, including controls over management's review of cost to complete and variable consideration estimates. <br>Our audit procedures included, among others, evaluating the appropriate application of the Company's revenue recognition method; testing significant assumptions used to develop estimated variable consideration recognized with respect to potential customer claims, backcharges and penalties and forecasted cost reductions associated with expected subcontractor backcharge recoveries; and testing the completeness and accuracy of the underlying data. To assess the reasonableness of these estimates, we performed audit procedures that included, among others, agreeing the estimates to supporting documentation; conducting interviews with project personnel; observing select project review meetings; and performing sensitivity analyses or retrospective review using historical data and trends. |

---

/s/ Ernst & Young LLP

We have served as the Company's auditor since 1973.

Dallas, Texas

February 17, 2026

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**CONSOLIDATED STATEMENT OF OPERATIONS**

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>**(in millions, except per share amounts)** | **2025** | **2024** | **2023** |
| Revenue | $15503 | $16315 | $15474 |
| Cost of revenue | (15623) | (15741) | (14997) |
| &nbsp;&nbsp;&nbsp;&nbsp;Gross profit (loss) | (120) | 574 | 477 |
| G&A | (196) | (203) | (232) |
| Foreign currency gain (loss) | (62) | 92 | (98) |
| &nbsp;&nbsp;&nbsp;&nbsp;Operating profit (loss) | (378) | 463 | 147 |
| Interest expense | (42) | (46) | (60) |
| Interest income | 109 | 196 | 228 |
| Earnings (loss) before taxes | (311) | 613 | 315 |
| Income tax benefit (expense) (including $92 million and $(376) million attributable to equity method earnings in 2025 and 2024, respectively)  | 39 | (634) | (236) |
| Net earnings (loss) before equity method earnings | (272) | (21) | 79 |
| Equity method earnings | 210 | 2105 |  |
| Net earnings (loss) | (62) | 2084 | 79 |
| Less: Net earnings (loss) attributable to NCI | (11) | (61) | (60) |
| Net earnings (loss) attributable to Fluor | $(51) | $2145 | $139 |
| Less: Dividends on CPS |  |  | 29 |
| Less: Make-whole payment on conversion of CPS |  |  | 27 |
| Net earnings (loss) available to Fluor common stockholders | $(51) | $2145 | $83 |
| Basic EPS available to Fluor common stockholders | $(0.31) | $12.48 | $0.55 |
| Diluted EPS available to Fluor common stockholders | $(0.31) | $12.30 | $0.54 |

---

*The accompanying notes are an integral part of these financial statements.*

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**CONSOLIDATED STATEMENT OF COMPREHENSIVE INCOME**

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>**(in millions)** | **2025** | **2024** | **2023** |
| Net earnings (loss) | (62) | 2084 | 79 |
| OCI, net of tax: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Foreign currency translation adjustment | 80 | (60) | 99 |
| &nbsp;&nbsp;&nbsp;&nbsp;Ownership share of equity method investees' OCI | 6 | (13) | (7) |
| &nbsp;&nbsp;&nbsp;&nbsp;Other | (1) | (5) | 2 |
| Total OCI, net of tax | 85 | (78) | 94 |
| Comprehensive income | 23 | 2006 | 173 |
| Less: Comprehensive income (loss) attributable to NCI | (11) | (57) | (63) |
| Comprehensive income attributable to Fluor | $34 | $2063 | $236 |

---

*The accompanying notes are an integral part of these financial statements.*

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**CONSOLIDATED BALANCE SHEET**

---

| | | |
|:---|:---|:---|
| **(in millions, except share and per share amounts)** | **December 31, 2025** | **December 31, 2024** |
| **ASSETS** | **ASSETS** | **ASSETS** |
| **Current assets** | | |
| Cash and cash equivalents ($328 and $333 related to VIEs) | $2135 | $2829 |
| Marketable securities | 59 | 130 |
| Accounts receivable, net ($142 and $92 related to VIEs) | 1073 | 921 |
| Contract assets ($17 and $130 related to VIEs) | 1146 | 1138 |
| Investment in NuScale<sup>(1)</sup> | 1579 |  |
| Other current assets ($26 and $32 related to VIEs) | 450 | 157 |
| Total current assets | 6442 | 5175 |
| **Noncurrent assets** |  |  |
| PP&E, net ($41 and $46 related to VIEs) | 464 | 494 |
| Investments | 543 | 2828 |
| Other assets ($17 related to VIEs for both periods) | 787 | 646 |
| Total noncurrent assets | 1794 | 3968 |
| **Total assets** | $8236 | $9143 |
| **LIABILITIES AND EQUITY** | **LIABILITIES AND EQUITY** | **LIABILITIES AND EQUITY** |
| **Current liabilities** |  |  |
| Accounts payable ($205 and $233 related to VIEs) | $1482 | $1220 |
| Contract liabilities ($254 and $278 related to VIEs) | 633 | 684 |
| Accrued salaries, wages and benefits ($9 and $18 related to VIEs) | 621 | 640 |
| Other accrued liabilities ($31 and $37 related to VIEs) | 642 | 527 |
| Total current liabilities | 3378 | 3071 |
| Long-term debt | 1070 | 1104 |
| Deferred taxes | 6 | 468 |
| Other noncurrent liabilities ($3 related to VIEs for both periods) | 505 | 508 |
| **Contingencies and commitments** |  |  |
| **Equity** |  |  |
| &nbsp;&nbsp;&nbsp;**Shareholders' equity** |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Common stock — authorized 375,000,000 shares ($0.01 par value); issued and outstanding — 152,047,739 and 169,228,759 shares in 2025 and 2024, respectively | 2 | 2 |
| &nbsp;&nbsp;&nbsp;&nbsp;APIC | 443 | 1174 |
| &nbsp;&nbsp;&nbsp;&nbsp;AOCI | (265) | (351) |
| &nbsp;&nbsp;&nbsp;&nbsp;Retained earnings | 3064 | 3124 |
| &nbsp;&nbsp;&nbsp;&nbsp;Total shareholders' equity | 3244 | 3949 |
| &nbsp;&nbsp;&nbsp;&nbsp;NCI | 33 | 43 |
| &nbsp;&nbsp;&nbsp;&nbsp;Total equity | 3277 | 3992 |
| **Total liabilities and equity** | $8236 | $9143 |

---

*The accompanying notes are an integral part of these financial statements.*

(1) Our investment in NuScale was included in Investments as of December 31, 2024.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**CONSOLIDATED STATEMENT OF CASH FLOWS**

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>**(in millions)** | **2025** | **2024** | **2023** |
| **OPERATING CASH FLOW** |  |  |  |
| Net earnings (loss) | $(62) | $2084 | $79 |
| Adjustments to reconcile net earnings (loss) to operating cash flow: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Equity method earnings, net of taxes | (302) | (1729) |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Depreciation and amortization | 68 | 73 | 74 |
| &nbsp;&nbsp;&nbsp;&nbsp;(Gain) loss on sales of assets | (7) | (14) | 150 |
| &nbsp;&nbsp;&nbsp;&nbsp;Stock-based compensation | 30 | 31 | 48 |
| &nbsp;&nbsp;&nbsp;&nbsp;Deferred taxes | (511) | 42 | (13) |
| Changes in assets and liabilities | 402 | 347 | (114) |
| Other | (5) | (6) | (12) |
| Operating cash flow<sup>(1)</sup> | (387) | 828 | 212 |
| **INVESTING CASH FLOW** |  |  |  |
| Proceeds from the sale of NuScale shares | 605 |  |  |
| Purchases of marketable securities | (146) | (205) | (426) |
| Proceeds from sales and maturities of marketable securities | 221 | 145 | 285 |
| Capital expenditures | (50) | (164) | (106) |
| NuScale cash deconsolidated |  | (131) |  |
| Proceeds from sales of assets (net of cash divested) | 63 | 82 | (5) |
| Investments in partnerships and joint ventures | (278) | (93) | (33) |
| Return of capital from partnerships and joint ventures | 22 | 34 | 8 |
| Other |  | (1) |  |
| Investing cash flow | 437 | (333) | (277) |
| **FINANCING CASH FLOW** |  |  |  |
| Repurchase of common stock | (754) | (125) |  |
| Proceeds from issuance of 2029 Notes, net of issuance costs |  |  | 560 |
| Capped call transactions related to 2029 Notes |  |  | (73) |
| Purchases and retirement of debt | (37) | (57) | (249) |
| Proceeds from NuScale share issuance (net of issuance fees) |  | 80 |  |
| Dividends paid on CPS |  |  | (29) |
| Make-whole payment on conversion of CPS |  |  | (27) |
| Distributions paid to NCI | (64) | (14) | (53) |
| Capital contributions by NCI | 65 |  | 10 |
| Other | (7) |  | (12) |
| Financing cash flow | (797) | (116) | 127 |
| Effect of exchange rate changes on cash | 53 | (69) | 18 |
| Increase (decrease) in cash and cash equivalents | (694) | 310 | 80 |
| Cash and cash equivalents at beginning of year | 2829 | 2519 | 2439 |
| Cash and cash equivalents at end of year | $2135 | $2829 | $2519 |

---

*The accompanying notes are an integral part of these financial statements.*

(1) Operating cash flow in 2025 included a payment of $642 million to Santos, net of insurance recoveries, for a judgment related to a reimbursable project completed by us in 2015.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**CONSOLIDATED STATEMENT OF CHANGES IN EQUITY**

---

| | | | | | | | | | | |
|:---|:---|:---|:---|:---|:---|:---|:---|:---|:---|:---|
| &nbsp;&nbsp;&nbsp;**(in millions, except per share amounts)** | **Preferred Stock** | **Preferred Stock** | **Common Stock** | **Common Stock** | **APIC** | **AOCI** | **Retained<br>Earnings** | **Total Shareholders' Equity** | **NCI** | **Total<br>Equity** |
| &nbsp;&nbsp;&nbsp;**(in millions, except per share amounts)** | **Shares** | **Amount** | **Shares** | **Amount** | **APIC** | **AOCI** | **Retained<br>Earnings** | **Total Shareholders' Equity** | **NCI** | **Total<br>Equity** |
| BALANCE AS OF <br>DECEMBER 31, 2022 | 1 | $— | 142 | $1 | $1254 | $(365) | $896 | $1786 | $210 | $1996 |
| Net earnings (loss) |  |  |  |  |  |  | 139 | 139 | (60) | 79 |
| OCI |  |  |  |  |  | 96 |  | 96 | (2) | 94 |
| Dividends on CPS ($48.75 per share) |  |  |  |  |  |  | (29) | (29) |  | (29) |
| Conversion of CPS to common stock (including make-whole payment) | (1) |  | 27 | 1 |  |  | (27) | (26) |  | (26) |
| Capped call transactions related to 2029 Notes |  |  |  |  | (73) |  |  | (73) |  | (73) |
| Distributions to NCI, net of contributions |  |  |  |  |  |  |  |  | (43) | (43) |
| Other NCI transactions |  |  |  |  | 14 |  |  | 14 | 7 | 21 |
| Stock-based plan activity |  |  | 1 |  | 33 |  |  | 33 |  | 33 |
| BALANCE AS OF <br>DECEMBER 31, 2023 |  | $— | 170 | $2 | $1228 | $(269) | $979 | $1940 | $112 | $2052 |
| Net earnings (loss) |  |  |  |  |  |  | 2145 | 2145 | (61) | 2084 |
| OCI |  |  |  |  |  | (82) |  | (82) | 4 | (78) |
| Distributions to NCI, net of contributions |  |  |  |  |  |  |  |  | 29 | 29 |
| Other NCI transactions |  |  |  |  | 44 |  |  | 44 | (41) | 3 |
| Stock-based plan activity |  |  | 1 |  | 27 |  |  | 27 |  | 27 |
| Repurchase of common stock |  |  | (2) |  | (125) |  |  | (125) |  | (125) |
| BALANCE AS OF <br>DECEMBER 30, 2024 |  | $— | 169 | $2 | $1174 | $(351) | $3124 | $3949 | $43 | $3992 |
| Net earnings (loss) |  |  |  |  |  |  | (51) | (51) | (11) | (62) |
| OCI |  |  |  |  |  | 86 |  | 86 | (1) | 85 |
| Contributions from NCI, net of distributions |  |  |  |  |  |  |  |  | 2 | 2 |
| Stock-based plan activity |  |  | 1 |  | 23 |  |  | 23 |  | 23 |
| Repurchase of common stock |  |  | (18) |  | (754) |  | (9) | (763) |  | (763) |
| BALANCE AS OF <br>DECEMBER 30, 2025 |  | $— | 152 | $2 | $443 | $(265) | $3064 | $3244 | $33 | $3277 |

---

*The accompanying notes are an integral part of these financial statements.*

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)[&nbsp;&nbsp;&nbsp;&nbsp;](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS**

**1.&nbsp;&nbsp;&nbsp;&nbsp;Description of Business**

Through our subsidiaries and joint ventures, we stand among the world's leading professional services firms, offering EPC and project management services. We provide these services to our clients in diverse industries worldwide including life sciences, advanced technologies and manufacturing, data centers, mining and metals, gas and nuclear derived power, infrastructure, chemicals, LNG, and oil and gas production and fuels. We are also a service provider to the U.S. federal government and governments abroad.

Our operations are organized into 3 principal segments: Urban Solutions, Energy Solutions and Mission Solutions. Additional activities are reported under our Other segment.

Urban Solutions provides EPC and project management services to the advanced technologies and manufacturing, life sciences, mining and metals, infrastructure industries and via professional staffing services. This segment also includes our operations and maintenance business.

Energy Solutions offers EPC services for traditional oil and gas markets, including the production and fuels, chemicals, LNG and power markets. The segment serves these industries with comprehensive project life-cycle services, including expansion and modernization projects as well as in sustaining capital work. The segment also supports energy transition markets, including nuclear power and other low-carbon energy sources, asset decarbonization, carbon capture, renewable fuels, green chemicals and hydrogen.

Mission Solutions delivers advanced technical services to the U.S. and other governments. This segment works with the DOE and the National Nuclear Security Administration, the DOD, FEMA and intelligence agencies. The segment also provides services to commercial nuclear clients.

**2.&nbsp;&nbsp;&nbsp;&nbsp;Significant Accounting Policies**

*Principles of Consolidation*

The financial statements include the accounts of Fluor Corporation and its subsidiaries. All intercompany transactions of consolidated subsidiaries are eliminated. Certain amounts in 2024 and 2023 have been reclassified to conform to the 2025 presentation. Certain amounts in tables may not total or agree to the financial statements due to immaterial rounding differences. Management has evaluated all material events occurring subsequent to December 31, 2025 through the filing date of the 2025 10-K.

We frequently form joint ventures or partnerships with others primarily for the execution of single contracts or projects. If a joint venture or partnership is a VIE and we are the primary beneficiary, the joint venture or partnership is consolidated and our partners' interests are recognized as NCI. As is customary in our industry, for unconsolidated construction partnerships and joint ventures, we generally recognize our proportionate share of revenue, cost and profit and use the one-line equity method for the investment. In other instances, the cost and equity methods of accounting are used, depending on our respective ownership interest and amount of influence we have over the entity, as well as other factors. At times, we also execute projects through collaborative arrangements for which we recognize our relative share of revenue and cost.

*Equity Method Investment with Fair Value Option*

We elected the fair value option of accounting for our investment in NuScale that would have otherwise been recorded under the equity method of accounting. We recognize the fair value of our investment in NuScale on a mark-to-market basis based upon the prevailing price of their stock on our balance sheet dates. The changes in the fair value of our investment in NuScale are recorded quarterly in the statement of operations.

*Use of Estimates*

The preparation of financial statements in accordance with GAAP requires management to make estimates and assumptions that affect reported amounts. These estimates are based on information available through the date of the issuance of the financial statements. Therefore, actual results could differ from those estimates.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

*Earnings Per Share*

Potentially dilutive securities include convertible debt, performance-based award units, RSUs, stock options and, prior to their conversion in 2023, our CPS. Diluted EPS reflects the assumed exercise or conversion of all dilutive securities using the if-converted and treasury stock methods. In computing diluted EPS, only securities that are actually dilutive are included.

*Foreign Currency Translation*

Our reporting currency is the U.S. dollar. For our international subsidiaries, the functional currency is typically the currency of the primary economic environment in which each subsidiary operates. Translation gains and losses are recorded in OCI. Gains and losses from remeasuring foreign currency transactions into the functional currency are recognized in earnings.

*Revenue Recognition*

*Engineering and construction contracts.* We recognize engineering and construction contract revenue over time as we provide services to satisfy our performance obligations. We generally use the cost-to-cost percentage-of-completion measure of progress as it best depicts how control transfers to our clients. The cost-to-cost approach measures progress towards completion based on the ratio of cost incurred to date compared to total estimated contract cost. Engineering and construction contracts are generally accounted for as a single unit of account (a single performance obligation) and are not segmented between types of services on a single project. Cost of revenue includes an allocation of depreciation and amortization. Where applicable, CFM, labor and equipment as well as subcontractor materials, labor and equipment, are included in revenue and cost of revenue when we believe that we are acting as a principal rather than as an agent (i.e., we integrate the materials, labor and equipment into the deliverables promised to the customer). CFM are only included in revenue and cost when the contract includes construction activity and we have visibility into the amount the customer is paying for the materials or there is a reasonable basis for estimating the amount. If we lose visibility mid-project with respect to cost or receipt, we cease recognizing future CFM but do not de-recognize previous amounts of CFM. Changes to total estimated contract cost or losses, if any, are recognized in the period in which they are determined as assessed at the contract level. Pre-contract costs are expensed as incurred unless they are expected to be recovered from the client. Project mobilization costs are generally charged to project costs as incurred when they are an integrated part of the performance obligation being transferred to the client. Customer payments on engineering and construction contracts are typically due within 30 to 45 days of billing, depending on the contract.

*Service Contracts.* If we have a right to consideration from a customer in an amount that corresponds directly with the value of our performance completed to date (a service contract in which we bill a fixed amount for each hour of service provided), we recognize revenue in the amount to which we have a right to invoice for services performed. For the majority of our operations and maintenance contracts, revenue is recognized when services are performed and contractually billable. For all other service contracts, we recognize revenue over time using the cost-to-cost percentage-of-completion method. Service contracts that include multiple performance obligations are segmented between types of services. For contracts with multiple performance obligations, we allocate the transaction price to each performance obligation using an estimate of the stand-alone selling price of each distinct service in the contract. Customer payments on service contracts are typically due within 30 to 90 days of billing, depending on the contract.

*Other.* We generally provide limited duration warranties for work performed under our contracts. Historically, warranty claims have not resulted in material costs incurred, and any estimated costs for warranties are included in the individual project cost estimates for purposes of accounting for long-term contracts.

We do not adjust the contract price for the effects of a significant financing component where, at contract inception, the period between service provision and customer payment will be 1 year or less.

We exclude from the measurement of the transaction price all taxes assessed by governmental authorities that are collected by us from our customers (use taxes, value added taxes, some excise taxes). *RUPO.* RUPO represents a measure of the value of work to be performed on contracts awarded and in progress. Although RUPO reflects business that is considered to be firm, cancellations, deferrals or scope adjustments may occur. RUPO is adjusted to reflect any known project cancellations, revisions to project scope and cost, foreign currency exchange fluctuations and project deferrals, as appropriate. RUPO includes estimates of CFM in those instances where the criteria for recognition have been satisfied. RUPO includes only the amount of revenue we expect to recognize under contracts with definite terms and substantive termination provisions. Most of our contracts are subject to termination at the discretion of our client but typically provide for the

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

payment of fees earned through the date of termination and the reimbursement of other costs incurred including demobilization costs, which typically represent substantive penalties for purposes of determining the duration of our contracts.

*Project Estimates.* Due to the nature of our industry, there is significant complexity in our estimation of total expected revenue and cost, for which we must make significant judgments. Our contracts with our customers may contain several types of variable consideration, including claims, unpriced change orders, award and incentive fees, liquidated damages and penalties or other provisions that can either increase or decrease the contract price to arrive at estimated revenue. Certain variable consideration, such as award and incentive fees, generally are earned upon achievement of certain performance metrics, program milestones or cost targets and can be based upon customer discretion. We estimate variable consideration at the most likely amount to which we expect to be entitled upon completion of a project. We include estimated amounts in the transaction price to the extent it is probable we will realize that amount. Our estimates of variable consideration and our determination of its inclusion in project revenue are based on an assessment of our anticipated performance and other information that may be available to us.

&nbsp;&nbsp;&nbsp;&nbsp;At a project level, we have specific practices and procedures to review our estimate of total revenue and cost. Each project team reviews the progress and execution of our performance obligations, which impact the project's accounting outcome. As part of this process, the project team reviews information such as any outstanding key contract matters, progress towards completion and the related program schedule and identified risks and opportunities. The accuracy of our revenue and profit recognition in a given period depends on the accuracy of our project estimates, which can change from period to period due to a variety of factors including:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Complexity in original design;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Extent of changes from original design;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Different site conditions than assumed in our bid;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The productivity, availability and skill level of labor;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Weather conditions when executing a project;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• The technical maturity of the technologies involved;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Length of time to complete the project;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Availability and cost of equipment and materials;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Subcontractor and joint venture partner performance;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Expected costs of warranties; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Our ability to recover for additional contract costs.

&nbsp;&nbsp;&nbsp;&nbsp;We recognize changes in contract estimates on a cumulative catch-up basis in the period in which the changes are identified. Such changes in contract estimates can result in the recognition of revenue in a current period for performance obligations which were satisfied or partially satisfied in prior periods. Changes in contract estimates may also result in the reversal of previously recognized revenue if the current estimate adversely differs from the previous estimate. If we estimate that a project will have costs in excess of revenue, we recognize the total loss in the period it is identified.

*Contract Assets and Liabilities*

&nbsp;&nbsp;&nbsp;&nbsp;Contract assets represent revenue recognized in excess of amounts billed and include unbilled receivables (typically for cost reimbursable contracts) and contract work in progress (typically for fixed-price contracts). Unbilled receivables, which represent an unconditional right to payment subject only to the passage of time, are recognized as accounts receivable when they are billed. We anticipate that substantially all incurred cost associated with contract assets as of December 31, 2025 will be billed and collected within 1 year. Contract liabilities represent amounts billed to clients in excess of revenue recognized to date.

*Segment Reporting*

Our Chief Executive Officer is our CODM. Segment profit is an earnings measure that our CODM utilizes to assess segment performance and allocate resources, primarily employees, to our segments. Segment profit is calculated as revenue less cost of revenue and earnings attributable to NCI.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

We incur cost and expenses and hold certain assets at the corporate level which relate to our business as a whole. Certain of these amounts are allocated to our business segments by various methods, largely on the basis of estimated usage or on pro rata revenue. Total assets not allocated to segments and held in "Corporate and other" primarily include cash, marketable securities, income-tax related assets, deferred compensation trust assets and corporate property, plant and equipment.

*Variable Interest Entities*

We assess our partnerships and joint ventures at inception to determine if any meet the qualifications of a VIE. We consider a partnership or joint venture a VIE if it has any of the following characteristics:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;(a) the total equity investment is not sufficient to permit the entity to finance its activities without additional subordinated financial support,

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;(b) characteristics of a controlling financial interest are missing (either the ability to make decisions through voting or other rights, the obligation to absorb the expected losses of the entity or the right to receive the expected residual returns of the entity), or

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;(c) the voting rights of the equity holders are not proportional to their obligations to absorb the expected losses of the entity and/or their rights to receive the expected residual returns of the entity, and substantially all of the entity's activities either involve or are conducted on behalf of an investor that has disproportionately few voting rights.

We regularly reassess our initial determination of whether the partnership or joint venture is a VIE. The majority of our partnerships and joint ventures qualify as VIEs because the total equity investment is typically nominal and not sufficient to permit the entity to finance its activities without additional subordinated financial support.

We also perform a qualitative assessment of each identified VIE to determine if we are its primary beneficiary. We conclude that we are the primary beneficiary and consolidate the VIE if we have both:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;(a) the power to direct the economically significant activities of the entity and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;(b) the obligation to absorb losses of, or the right to receive benefits from, the entity that could potentially be significant to the VIE.

We consider the contractual agreements that define the ownership structure, distribution of profits and losses, risks, responsibilities, indebtedness, voting rights and board representation of the respective parties in determining if we are the primary beneficiary. We also consider all parties that have direct or implicit variable interests when determining whether we are the primary beneficiary. Management's assessment of who is the primary beneficiary of a VIE is regularly undertaken.

*Cash and Cash Equivalents*

Cash and cash equivalents include securities with maturities of 3 months or less at the date of purchase.

*Marketable Securities*

Marketable securities consist of time deposits placed with investment grade banks with original maturities greater than 3 months, which are typically held-to-maturity because we have the intent and ability to hold them until maturity. Held-to-maturity securities are carried at amortized cost. The cost of securities sold is determined by using the specific identification method. Marketable securities are assessed at least annually for other-than-temporary impairment.

*Property, Plant and Equipment*

Property, plant and equipment is recorded at cost. Leasehold improvements are amortized over the shorter of their economic lives or the lease terms. Depreciation is calculated using the straight-line method over the following ranges of estimated useful service lives, in years:

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

---

| | |
|:---|:---|
| | **Estimated Useful Service Lives** |
| | **Estimated Useful Service Lives** |
| &nbsp;&nbsp;&nbsp;Buildings | 20 – 40 |
| &nbsp;&nbsp;&nbsp;Building and leasehold improvements | 6 – 20 |
| &nbsp;&nbsp;&nbsp;Machinery and equipment | 2 – 10 |
| &nbsp;&nbsp;&nbsp;Furniture and fixtures | 2 – 10 |

---

*Income Taxes*

Deferred tax assets and liabilities are recognized for the expected future tax consequences of events that have been recognized in our financial statements or tax filings. We evaluate the realizability of our deferred tax assets and record a valuation allowance to reduce deferred tax assets to amounts that are more likely than not to be realized. The factors used to assess the likelihood of realization are our forecast of future taxable income and available tax planning strategies that could be implemented to realize such assets. Failure to achieve forecasted taxable income could affect the ultimate realization of deferred tax assets and could adversely impact our future effective tax rate.

Income tax positions are recognized when they meet a more-likely-than-not recognition threshold. Previously recognized tax positions that no longer meet the more-likely-than-not threshold are derecognized upon such determination. We recognize potential interest and penalties related to unrecognized tax positions as a component of income tax expense.

Judgment is required in determining the provision for income taxes as we consider our worldwide taxable earnings and the impact of the continuing audit process conducted by relevant tax authorities. The final outcome of any audits could differ materially from amounts recognized by us. We account for the GILTI effects in the period that is subject to such tax.

*Embedded Derivatives*

We attempt to limit foreign currency exposure in most of our contracts by denominating contract revenue in the currencies in which cost is incurred. In certain limited circumstances, foreign currency payment provisions could be deemed embedded derivatives. If an embedded foreign currency derivative is identified, the derivative is bifurcated from the host contract and the change in fair value is recognized through earnings.

*Concentrations of Credit Risk*

Accounts receivable and all contract work in progress are from clients in various industries and locations throughout the world. Most contracts require payments as the projects progress or, in certain cases, advance payments. We generally do not require collateral, but in most cases can place liens against the project assets or terminate the contract, if a material default occurs. We evaluate the counterparty credit risk as part of our bidding process, our project risk review process and in determining the appropriate level of reserves during project execution. We maintain reserves for potential credit losses and generally such losses have been minimal and within management's estimates.

We have cash and marketable securities on deposit with major banks throughout the world. Such deposits are placed with high quality institutions and the amounts invested in any single institution are limited to the extent possible in order to minimize concentration of counterparty credit risk.

We monitor the credit quality of our counterparties and establish reserves for any significant credit risk losses.

*Stock-Based Compensation*

Generally, our annual grant of stock-based awards to employees are made on a broad basis in the first quarter and to our Board of Directors in the second quarter. Our stock plans provide for grants of performance-based award units, RSUs and nonqualified or incentive stock options. Grants of performance-based units awarded to Section 16 officers, RSUs and stock options can only be settled in company stock and are accounted for as equity awards.

All expense under stock-based awards is recognized based on the fair values of the awards. The grant date fair value of performance-based award units is determined by adjusting the closing price of our common stock on the date of grant for the effect of market conditions. The fair value of grants of RSUs is determined using the closing price of our common stock on the date of grant. Stock option awards have exercise prices equal to the grant date market price of our stock. Stock-based

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

compensation expense is generally recognized over the required service period, or over a shorter period when the grantee is or becomes retirement eligible.

We also grant SGI awards and performance-based awards to non-Section 16 executives which are settled in cash. These awards are classified as liabilities and remeasured at fair value through expense at the end of each reporting period until the awards are settled.

**3.&nbsp;&nbsp;&nbsp;&nbsp;Recent Accounting Pronouncements**

In 2025, we adopted ASU 2023-05, which requires certain joint ventures to apply a new basis of accounting upon formation by recognizing and initially measuring most of their assets and liabilities at fair value. The guidance does not apply to joint ventures that may be proportionately consolidated and those that are collaborative arrangements. The adoption did not have any impact on our consolidated results.

In 2025, we adopted ASU 2023-09 on a prospective basis. This ASU requires us to disclose income taxes paid, net of refunds, disaggregated by federal, state and foreign taxes and to provide more details in our rate reconciliation about items that meet a quantitative threshold. The adoption did not have any impact on our consolidated results.

During 2024, the FASB issued ASU 2024-03 on the disaggregation of income statement expenses or "DISE." This ASU requires additional footnote disclosure of the details of certain income statement expense line items, without changing amounts reported on the consolidated income statement. ASU 2024-03 is first effective for our annual reporting for 2027 and for our quarterly reporting beginning in 2028. We do not expect this ASU to have any impact on our consolidated results.

In May 2025, the FASB issued ASU 2025-03 on identifying the accounting acquirer in transactions involving VIEs. This ASU revises the guidance to require consideration of the same factors used in other business combinations when the legal acquiree is a VIE that qualifies as a business and the transaction is effected primarily through the exchange of equity interests. ASU 2025-03 is effective for our annual and quarterly reporting for 2027. We do not expect this ASU to have any impact on our consolidated results.

In July 2025, the FASB issued ASU 2025-05 on measurement of credit losses for accounts receivable and contract assets. This ASU introduces a practical expedient allowing us to assume that conditions at the balance sheet date remain unchanged over the life of these assets. ASU 2025-05 is effective prospectively for our annual and quarterly reporting for 2026. We do not expect this ASU to have any impact on our consolidated results.

In September 2025, the FASB issued ASU 2025-06 to make targeted improvements to the guidance on internal use software. This ASU removes all references to project stages in ASC 350-40 and clarifies the threshold entities apply to begin capitalizing costs. ASU 2025-06 is effective for our annual and quarterly reporting for 2028 and may be applied using a prospective, retrospective or modified transition approach. We are assessing any impact this ASU may have on our consolidated results.

In December 2025, the FASB issued ASU 2025-11 on interim reporting. This ASU clarifies when interim reporting requirements apply, standardizes the form and content of interim financial statements and notes, and introduces a disclosure principle requiring entities to report events occurring after year end that have a material impact. ASU 2025-11 is effective for our annual and quarterly reporting for 2028. We do not expect this ASU to have any impact on our consolidated results.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

**4.&nbsp;&nbsp;&nbsp;&nbsp;Earnings Per Share**

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
| **(in millions, except per share amounts)** | **2025** | **2024** | **2023** |
| &nbsp;&nbsp;&nbsp;&nbsp;Net earnings (loss) attributable to Fluor | $(51) | $2145 | $139 |
| &nbsp;&nbsp;&nbsp;&nbsp;Less: Dividends on CPS |  |  | 29 |
| &nbsp;&nbsp;&nbsp;&nbsp;Less: Make-whole payment on conversion of CPS |  |  | 27 |
| &nbsp;&nbsp;&nbsp;&nbsp;Net earnings (loss) available to Fluor common stockholders | $(51) | $2145 | $83 |
| &nbsp;&nbsp;&nbsp;&nbsp;Weighted average common shares outstanding | 164 | 172 | 150 |
| &nbsp;&nbsp;&nbsp;&nbsp;Dilutive effect: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Performance-based award units, RSUs and stock options |  | 2 | 3 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Convertible debt <sup>(1)</sup> |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Weighted average diluted shares outstanding | 164 | 174 | 153 |
| &nbsp;&nbsp;&nbsp;&nbsp;Basic EPS available to Fluor common stockholders | $(0.31) | $12.48 | $0.55 |
| &nbsp;&nbsp;&nbsp;&nbsp;Diluted EPS available to Fluor common stockholders | $(0.31) | $12.30 | $0.54 |
| &nbsp;&nbsp;&nbsp;&nbsp;Anti-dilutive securities not included in shares outstanding: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp; CPS |  |  | 20 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Performance-based award units, RSUs and stock options | 3 | 1 | 2 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Stock delivered under capped call options <sup>(2)</sup> |  |  |  |

---

(1) Holders of our 2029 Notes may convert their notes at a conversion price of $45.37 per share when the stock price exceeds $58.98 for 20 of the last 30 days preceding quarter end. Upon conversion, we will repay the principal amount of the notes in cash and may elect to convey the conversion premium in cash, shares of our common stock or a combination of both. The conversion feature of our 2029 Notes has a dilutive impact on EPS when the average market price of our common stock exceeds the conversion price of $45.37 per share for the quarter. During 2025 and 2023, the weighted average price of our common stock was below the minimum conversion price. During 2024, the weighted average price of our common stock exceeded $45.37 resulting in the addition of 575,000 shares to diluted shares outstanding.

(2) Diluted shares outstanding does not include the impact of the capped call options we entered into concurrently with the issuance of the 2029 Notes, as the effect is always anti-dilutive. If shares are delivered to us under the capped calls, those shares will offset the dilutive effect of the shares that we would issue upon conversion of the 2029 Notes.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

**5.&nbsp;&nbsp;&nbsp;&nbsp;Operating Information by Segment and Geographic Area**

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>**(in millions)** | **2025** | **2024** | **2023** |
| Revenue |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $9200 | $7239 | $5262 |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions | 3554 | 5976 | 6307 |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | 2720 | 2594 | 2655 |
| &nbsp;&nbsp;&nbsp;&nbsp;Other | 29 | 506 | 1250 |
| Total revenue | $15503 | $16315 | $15474 |
| Cost of revenue |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $(9018) | $(6931) | $(4978) |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions | (3963) | (5715) | (5942) |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | (2619) | (2427) | (2525) |
| &nbsp;&nbsp;&nbsp;&nbsp;Other | (23) | (668) | (1552) |
| Total cost of revenue | $(15623) | $(15741) | $(14997) |
| Segment profit (loss) |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $205 | $304 | $268 |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions | (414) | 256 | 381 |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | 94 | 153 | 116 |
| &nbsp;&nbsp;&nbsp;&nbsp;Other | 6 | (78) | (228) |
| Total segment profit (loss) | $(109) | $635 | $537 |
| G&A | (196) | (203) | (232) |
| Foreign currency gain (loss) | (62) | 92 | (98) |
| Interest income (expense), net | 67 | 150 | 168 |
| Earnings (loss) attributable to NCI | (11) | (61) | (60) |
| Earnings (loss) before taxes | $(311) | $613 | $315 |
| Depreciation (all but Corporate included in segment profit) |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $27 | $27 | $10 |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions | 29 | 24 |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | 8 | 5 | 3 |
| &nbsp;&nbsp;&nbsp;&nbsp;Other |  | 8 | 19 |
| &nbsp;&nbsp;&nbsp;&nbsp;Corporate | 4 | 9 | 42 |
| Total depreciation | $68 | $73 | $74 |
| Capital expenditures |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $17 | $21 | $20 |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | 4 | 3 | 4 |
| &nbsp;&nbsp;&nbsp;&nbsp;Other |  | 6 | 15 |
| &nbsp;&nbsp;&nbsp;&nbsp;Corporate | 29 | 134 | 67 |
| Total capital expenditures | $50 | $164 | $106 |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

---

| | | |
|:---|:---|:---|
| **(in millions)** | **December 31, 2025** | **December 31, 2024** |
| Total assets |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $1769 | $1472 |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions | 621 | 729 |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | 733 | 734 |
| &nbsp;&nbsp;&nbsp;&nbsp;Other | 1581 | 2338 |
| &nbsp;&nbsp;&nbsp;&nbsp;Corporate | 3532 | 3870 |
| Total assets | $8236 | $9143 |
| Goodwill |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;Urban Solutions | $130 | $129 |
| &nbsp;&nbsp;&nbsp;&nbsp;Energy Solutions | 12 | 13 |
| &nbsp;&nbsp;&nbsp;&nbsp;Mission Solutions | 58 | 58 |
| &nbsp;&nbsp;&nbsp;&nbsp;Other |  |  |
| Total goodwill | $200 | $199 |

---

***Urban Solutions.*** Revenue from a single customer amounted to 15% of consolidated revenue during 2025. Segment profit in 2025 decreased due to forecast adjustments for cost growth on 3 infrastructure projects related to subcontracted design errors, price escalation, schedule impacts partially offset by the refinement of expected recovery on these same projects. These forecast adjustments of $108 million (or $0.61 per share) were partially offset by improved performance on other infrastructure projects, a favorable negotiation with a designer on a separate infrastructure project and the ramp up of life sciences projects. Segment profit increased in 2024 due to the ramp up of several recently awarded projects, partially offset by cost growth on an infrastructure project. Segment profit in 2024 included an agreement to the terms of a change order on a legacy infrastructure project compared to a $59 million (or $0.34 per share) charge for rework associated with subcontractor design errors and related schedule impacts on the same project during 2023. Further, segment profit in 2023 included the favorable settlement of a claim on an international bridge project.

***Energy Solutions.*** Revenue from 2 customers each amounted to 10% of consolidated revenue during 2023. Segment profit declined in 2025 due to the reversal of previously recognized revenue of $643 million (or $3.89 per share) for a judgment on the long completed Santos project in Australia. Segment profit declined in 2024 primarily due to the initial recognition of inflation-adjusted variable consideration on certain downstream projects during 2023. Segment profit in 2024 was also impacted by cost growth related to schedule delays and reduced productivity on a large project in the late stages of execution. We recognized a positive adjustment upon the negotiation of change orders on the same project in 2023. Further, cost growth on a construction-only subcontract executed by our joint venture in Mexico resulted in charges totaling $66 million (or $0.26 per share) during 2024. The decrease in segment profit during 2024 was partially offset by final negotiations and handover of a large upstream legacy project which was completed during the second quarter of 2024. We recorded $91 million (or $0.53 per share) for cost growth on the now-completed project during 2023.

***Mission Solutions.*** Revenue from work performed for various agencies of the U.S. government amounted to 17%, 16% and 9% of consolidated revenue during 2025, 2024 and 2023, respectively. Segment profit declined in 2025 primarily due to the recognition of revenue reserves for certain disputed costs on a DOD project and an adverse ruling on a long-standing claim on a project completed in 2019.

Segment profit significantly improved during 2024 which reflected a $30 million (or $0.17 per share) charge for cost growth associated with schedule delays on a weapons facility project during 2023 that is now complete. The increase in segment profit and profit margin in 2024 was further driven by an increase in execution activities on a DOE contract partially offset by the cancellation of a project in 2023.

***Other***. Other included the results of NuScale prior to its deconsolidation in October 2024, and the remaining operations of Stork which was fully divested in 2025 and AMECO which was fully divested in 2023. Results from our Other segment were immaterial for 2025.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

Segment profit (loss) follows:

---

| | | |
|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>***(in millions)*** | **2024** | **2023** |
| NuScale | $(100) | $(106) |
| Stork | 23 | (55) |
| AMECO | (1) | (67) |
| Segment profit (loss) | $(78) | $(228) |

---

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;

**Operating Information by Geographic Area**

---

| | | | | | |
|:---|:---|:---|:---|:---|:---|
| | **Revenue by project location<br>Year Ended December 31,** | **Revenue by project location<br>Year Ended December 31,** | **Revenue by project location<br>Year Ended December 31,** | **Total Assets<br>As of December 31,** | **Total Assets<br>As of December 31,** |
|<br>**(in millions)** | **2025** | **2024** | **2023** | **2025** | **2024** |
| North America | $11314 | $11089 | $10514 | $6782 | $7459 |
| Asia Pacific (includes Australia) | 604 | 1837 | 1744 | 535 | 710 |
| Europe | 2895 | 2689 | 2268 | 494 | 568 |
| Central and South America | 538 | 484 | 741 | 135 | 133 |
| Middle East and Africa | 152 | 216 | 207 | 290 | 273 |
| &nbsp;&nbsp;&nbsp;Total | $15503 | $16315 | $15474 | $8236 | $9143 |

---

**6.&nbsp;&nbsp;&nbsp;&nbsp;Income Taxes** 

The components of income tax expense (benefit) are as follows:

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2024** | **2023** |
| &nbsp;&nbsp;&nbsp;Current: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Federal  | $235 | $(10) | $(3) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign | 138 | 214 | 240 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;State and local | 190 | 13 | 12 |
| &nbsp;&nbsp;&nbsp;Total current | 563 | 217 | 249 |
| &nbsp;&nbsp;&nbsp;Deferred: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Federal | (477) | 326 |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign | (37) | 19 | (13) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;State and local | (88) | 72 |  |
| &nbsp;&nbsp;&nbsp;Total deferred | (602) | 417 | (13) |
| &nbsp;&nbsp;&nbsp;Total income tax expense | $(39) | $634 | $236 |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

A reconciliation of U.S. statutory federal tax expense to total income tax benefit follows:

---

| | | |
|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2025** |
| &nbsp;&nbsp;U.S. statutory federal tax expense (includes equity method earnings) | $(21) | 21% |
| &nbsp;&nbsp;&nbsp;Increase (decrease) in taxes resulting from: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;State and local income taxes<sup>(1)</sup> | 61 | (60)% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign tax effects: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Australia: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Valuation allowance | 34 | (34)% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other | (11) | 11% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other foreign jurisdictions  | 60 | (59)% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Valuation allowance | (130) | 129% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign tax credits | (56) | 55% |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other, net | 24 | (24)% |
| &nbsp;&nbsp;Total income tax benefit | $(39) | 39% |

---

&nbsp;&nbsp;&nbsp;&nbsp;(1) State taxes in Alabama, Indiana, South Carolina made up the majority of the tax effect in this category for 2025.

A reconciliation of the provision for income taxes to the amount computed by applying the 21% of statutory U.S. federal income tax rate to income before income taxes for years prior to the adoption of ASU 2023-09 is as follows:

---

| | | |
|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>&nbsp;&nbsp;&nbsp;**(in millions)** | **2024** | **2023** |
| &nbsp;&nbsp;U.S. statutory federal tax expense (includes equity method earnings) | $571 | $66 |
| &nbsp;&nbsp;&nbsp;Increase (decrease) in taxes resulting from: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;State and local income taxes | 66 | 6 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Sale of foreign subsidiaries  |  | (10) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;NCI | 13 | 13 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign tax differential, net | 53 | 48 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Valuation allowance, net | (97) | 122 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other, net | 28 | (9) |
| &nbsp;&nbsp;&nbsp;Total income tax expense | $634 | $236 |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

Deferred taxes reflect the tax effects of differences between the amounts recorded as assets and liabilities for financial reporting purposes and the amounts recognized for income tax purposes. The tax effects of significant temporary differences giving rise to deferred tax assets and liabilities are as follows:

---

| | | |
|:---|:---|:---|
| | **December 31,** | **December 31,** |
|<br>&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2024** |
| &nbsp;&nbsp;&nbsp;Deferred tax assets: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Accrued liabilities not currently deductible: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Employee compensation and benefits | $86 | $98 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Project and non-project reserves | 22 | 50 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Revenue recognition | 52 | 44 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Net operating loss carryforward | 397 | 362 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Tax basis of investment in excess of book basis, net | 473 | 135 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;U.S. foreign tax credit carryforward | 331 | 663 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;AOCI | 27 | 29 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other | 85 | 92 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Total deferred tax assets | 1473 | 1473 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Valuation allowance | (1179) | (1241) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Deferred tax assets, net | $294 | $232 |
| &nbsp;&nbsp;&nbsp;Deferred tax liabilities: |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Book basis of property and equipment in excess of tax basis | (58) | (52) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Book basis of investments in excess of tax basis | (4) | (546) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Dividend withholding on unremitted foreign earnings | (54) | (59) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other | (13) | (13) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Total deferred tax liabilities | (129) | (670) |
| &nbsp;&nbsp;Net deferred tax assets (liabilities) | $165 | $(438) |

---

As of December 31, 2025, we intend to indefinitely reinvest the portion of unremitted foreign earnings required to support working capital and long-term investment needs in the jurisdictions where we operate. Earnings in excess of those requirements are expected to be available for distribution. We have not recorded deferred tax liabilities related to earnings that are designated as indefinitely reinvested, primarily for foreign withholding and income taxes that would be due upon remittance. We do not anticipate taking any actions that would result in the taxation of earnings for which we have asserted indefinite reinvestment.

As of December 31, 2025, tax credit carryforwards and tax loss carryforwards are as follows:

---

| | | | |
|:---|:---|:---|:---|
| &nbsp;&nbsp;**(in millions)** | **Federal FTC** | **State NOLs** | **Foreign NOLs** |
| &nbsp;&nbsp;Expiration periods: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;2026-2030 | $54 | $4 | $66 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;2031-2035 | 277 | 110 | 23 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;2036-2045 |  | 185 | 2 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Indefinite |  | 248 | 1360 |

---

During 2025, we were in a 3-year cumulative loss on a jurisdictional basis in the Australia, the Netherlands and the U.K. Such cumulative loss constitutes significant negative evidence (with regards to future taxable income) for assessing likelihood of realization. We also considered positive evidence but concluded it did not outweigh this significant negative evidence of a 3-year cumulative loss. Accordingly, we recognized non-cash charges to tax expense of 48 million against certain net foreign deferred tax assets during 2025. In 2025, all of NuScale's Class B voting common shares were converted into Class A common shares. For U.S. federal income tax purposes, the conversion was treated as a taxable capital transaction, resulting in the

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

recognition of approximately $3.7 billion of capital gain, which was included in the Company's taxable income for the year. To reduce the current tax liability associated with the recognized gain, the Company utilized prior-year foreign tax credits, capital loss carryforwards, and U.S. federal general business credits. In connection with the utilization of these tax attributes, the Company released $398 million of valuation allowances previously recorded against them. Following the recognition of the NuScale deferred gain, no additional sources of taxable income remained to support the realization of certain deferred tax assets. Based on management's assessment that these deferred tax assets are not more likely than not to be realized, the Company recorded a valuation allowance of $268 million during the year. The Company maintained a partial valuation allowance related to NuScale's deferred tax assets, as these attributes are expected to be carried back as capital losses to offset the current-year recognized capital gain.

In the normal course of business, we are subject to examination by taxing authorities worldwide, including such major jurisdictions as Australia, Canada, Chile, the Netherlands, the United Kingdom, and the United States. Although we believe our reserves for our tax positions are reasonable, the outcome of tax audits could be materially different, both favorably and unfavorably. With a few exceptions, we are no longer subject to U.S. federal, state and local, or foreign income tax examinations for years before 2012.

A summary of unrecognized tax benefits follows:

---

| | | |
|:---|:---|:---|
| &nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2024** |
| &nbsp;&nbsp;&nbsp;Balance at beginning of year | $33 | $52 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Change in tax positions of prior years |  | 15 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Change in tax positions of current year |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Reduction in tax positions for statute expirations |  | (1) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Reduction in tax positions for audit settlements | (2) | (33) |
| &nbsp;&nbsp;&nbsp;Balance at end of year | $31 | $33 |

---

If recognized, the total amount of unrecognized tax benefits as of December 31, 2025 and 2024, would favorably impact the effective tax rates by $13 million and $15 million, respectively. We had $22 million of accrued interest and penalties as of both December 31, 2025 and 2024.

U.S. and foreign earnings (loss) before taxes, including equity method earnings, are as follows:

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
| &nbsp;&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2024** | **2023** |
| &nbsp;&nbsp;&nbsp;United States | $(196) | $1589 | $185 |
| &nbsp;&nbsp;&nbsp;Foreign | 95 | 1129 | 130 |
| &nbsp;&nbsp;&nbsp;Total | $(101) | $2718 | $315 |

---

Cash paid for income taxes, net of refunds, was as follows:

---

| | |
|:---|:---|
| | **Year Ended December 31,** |
| &nbsp;&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Federal | $2 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;State and local: |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp; Other | 58 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Foreign: |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp; Canada | 69 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp; Other | 84 |
| &nbsp;&nbsp;Total cash paid for income taxes, net of refunds | $213 |

---

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

**7.&nbsp;&nbsp;&nbsp;&nbsp;Supplemental Cash Flow Information**

The changes in assets and liabilities included in operating cash flow follow:

---

| | | | |
|:---|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>&nbsp;&nbsp;&nbsp;&nbsp;**(in millions)** | **2025** | **2024** | **2023** |
| &nbsp;&nbsp;&nbsp;(Increase) decrease in: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Accounts and notes receivable, net | $(154) | $90 | $(87) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Contract assets | 12 | (227) | (72) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other current assets | (1691) | 159 | (12) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other assets | 1714 | 40 | (111) |
| &nbsp;&nbsp;&nbsp;Increase (decrease) in: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Accounts payable | 244 | 76 | 218 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Contract liabilities | (75) | 109 | (120) |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Accrued liabilities | 348 | 31 | 79 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Other liabilities | 4 | 69 | (9) |
| &nbsp;&nbsp;&nbsp;Increase (decrease) in cash due to changes in assets and liabilities | $402 | $347 | $(114) |
| &nbsp;&nbsp;Noncash investing and financing activities: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Marketable securities transferred to trustee to discharge the 2024 Notes | $— | $— | $262 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Debt assumed by buyer of Stork Latin America |  |  | 19 |
| &nbsp;&nbsp;&nbsp;Cash paid during the year for: |  |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Interest | $40 | $42 | $53 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Income taxes (net of refunds) | 213 | 13 | 169 |

---

**8.&nbsp;&nbsp;&nbsp;&nbsp;Partnerships and Joint Ventures** 

Many of our partnership and joint venture agreements provide for capital calls to fund operations, as necessary. Investments in a loss position of $47 million and $292 million were included in other accrued liabilities as of December 31, 2025 and 2024, respectively, and consisted primarily of provision for anticipated losses on a legacy infrastructure project and an Energy Solutions joint venture. Accounts receivable related to work performed for unconsolidated partnerships and joint ventures included in "Accounts receivable, net" were $219 million and $175 million as of December 31, 2025 and 2024, respectively.

In December 2025, we reached an agreement to sell our ownership in the fabrication yard in China for approximately $122 million.

*Variable Interest Entities*

The aggregate carrying value of unconsolidated VIEs (classified under both "Investments" and "Other accrued liabilities") was a net asset of $425 million and $2.4 billion as of December 31, 2025 and 2024, respectively. Some of our VIEs have debt; however, such debt is typically non-recourse to us. Our maximum exposure to loss as a result of our investments in unconsolidated VIEs is typically limited to the aggregate of the carrying value of the investment and future funding necessary to satisfy the contractual obligations of the VIE. Future funding commitments as of December 31, 2025 for the unconsolidated VIEs were $48 million.

We are required to consolidate certain VIEs. Assets and liabilities associated with the operations of our consolidated VIEs are presented on our balance sheet. The assets of a VIE are restricted for use only for the particular VIE and are not available for our general operations. We have agreements with certain VIEs to provide financial or performance assurances to clients, as discussed elsewhere.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

**9.&nbsp;&nbsp;&nbsp;&nbsp;Investment in NuScale**

Prior to November 2025, we converted 15 million of our 126 million NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares and sold all 15 million of those shares for net proceeds of $605 million. We converted the remaining 111 million of our NuScale voting shares (along with the associated ownership units in NuScale's operating subsidiary) into registered shares upon reaching agreement with NuScale in November 2025. In November 2025, through an indirect, wholly-owned subsidiary, we entered into a variable price forward sale agreement whereby we pledged and granted a security interest in 71 million of our remaining shares in NuScale, while maintaining continuing involvement and ownership rights, and committed to sell, convey, transfer, assign and deliver those shares at the final settlement date in the first quarter of 2026. Through our bank's execution, we completed the sale of all 71 million shares of NuScale on February 13, 2026, generating total proceeds of $1.35 billion.

The components of equity method earnings are as follows:

---

| | | |
|:---|:---|:---|
| | **Year Ended December 31,** | **Year Ended December 31,** |
|<br>***(in millions)*** | **2025** | **2024** |
| Equity method earnings |  |  |
| &nbsp;&nbsp;&nbsp;Gain (loss) on the fair value of our investment in NuScale | $(419) | $2221 |
| &nbsp;&nbsp;&nbsp;Gain on the fair value of the forward sale contract of NuScale shares | 208 |  |
| &nbsp;&nbsp;&nbsp;Gain on the sale of NuScale shares | 336 |  |
| &nbsp;&nbsp;&nbsp;Other | 85 | (116) |
| Equity method earnings | $210 | $2105 |

---

**10.&nbsp;&nbsp;&nbsp;&nbsp;Guarantees**

In the ordinary course of business, we enter into various agreements providing performance assurances and guarantees to our clients on behalf of certain unconsolidated and consolidated partnerships, joint ventures and other jointly executed contracts. These agreements are entered into primarily to support project execution commitments. Performance guarantees have various expiration dates ranging from mechanical completion to a period extending beyond contract completion. The maximum potential amount of future payments that we could be required to make under outstanding performance guarantees, which represents the remaining cost of work to be performed, was estimated to be $14 billion as of December 31, 2025. For cost reimbursable contracts, amounts that may become payable pursuant to guarantee provisions are normally recoverable from the client for work performed. For lump-sum contracts, the performance guarantee amount is the cost to complete the contracted work, less amounts remaining to be billed to the client under the contract. Remaining billable amounts could be greater or less than the cost to complete. In those cases where costs exceed the remaining amounts payable under the contract, we may have recourse to third parties, such as owners, partners, subcontractors or vendors for claims. The performance guarantees obligation was not material as of December 31, 2025 and 2024.

In certain limited circumstances, financial guarantees are entered into with financial institutions and other credit grantors and generally obligate us to make payment in the event of a default by the borrower. These arrangements generally require the borrower to pledge collateral to support the fulfillment of the borrower's obligation.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

**11.&nbsp;&nbsp;&nbsp;&nbsp;Contingencies and Commitments**

We and certain of our subsidiaries are subject to litigation, claims and other commitments and contingencies, including matters arising in the ordinary course of business, of which the asserted value may be significant. We record accruals in the financial statements for contingencies when we determine that an unfavorable outcome is probable and the amount of the loss can be reasonably estimated. While there is at least a reasonable possibility that other losses may be incurred in excess of amounts accrued, management is unable to estimate the possible loss or range of loss or has determined such amounts to be immaterial, except as otherwise noted below. At present, except as set forth below, we do not expect that the ultimate resolution of any open matters will have a material adverse effect on our financial position or results of operations. However, legal proceedings and regulatory and governmental matters are subject to inherent uncertainties, and unfavorable rulings or other events could occur. Unfavorable outcomes could involve substantial monetary damages, fines, penalties and other expenditures. An unfavorable outcome might result in a material adverse impact on our business, results of operations or financial position. We might also enter into an agreement to settle one or more such matters if we determine such settlement is in the best interests of our stakeholders, and any such settlement could include substantial payments.

Fluor Australia Ltd., our wholly-owned subsidiary ("Fluor Australia"), completed a cost reimbursable engineering, procurement and construction management services project for Santos Ltd. ("Santos") involving a large network of natural gas gathering and processing facilities in Queensland, Australia. On December 13, 2016, Santos filed an action in Queensland Supreme Court (the "Court") against Fluor Australia, asserting various causes of action and seeking damages and/or a refund of contract proceeds paid of AUD $1.47 billion. Santos joined Fluor to the matter on the basis of a parent company guarantee issued for the project. On July 14, 2023, a panel of 3 referees appointed by the Court (the "Panel") recommended judgment for Santos on claims that the Panel valued at approximately AUD $790 million excluding interest and costs. While the project contract contains a liability cap of approximately AUD $236 million, the Panel found that the liability cap did not apply to Santos's claims. Following interim applications and hearings, in August 2025, the Court generally accepted the recommendations of the panel of referees. In December 2025, we made a payment to Santos of $649 million, net of GST, in accordance with the Court's orders. Santos's legal fees will be assessed in a separate process. After allowing for committed insurance proceeds and reserves, we recognized a reduction to revenue of $643 million reflecting the net estimated impact of the judgment. Discussions with our insurers are ongoing and, if successful, may further reduce the ultimate obligation. We have appealed the court's decision to the Queensland Court of Appeal. The appeal hearing is currently scheduled to take place in July 2026. In mid-October 2025, five of our more than 30 insurers filed a complaint in the Superior Court of California, County of Orange, disputing coverage by seeking various declaratory judgments. We have reached an agreement with these carriers to dismiss the action without prejudice subject to a standstill/tolling agreement.

In September 2025, purported shareholders filed a complaint against Fluor and certain of its current and former executives in the U.S. District Court for the Northern District of Texas. The plaintiffs purport to represent a class of shareholders who purchased or otherwise acquired Fluor securities between February 18, 2025 and July 31, 2025, and seek to recover damages arising from alleged violations of federal securities laws. These claims are based on statements concerning market conditions, rising costs on three infrastructure projects and the effectiveness of our risk mitigation strategies, which statements the plaintiffs assert were materially misleading. We intend to contest these claims.

In October 2025, a purported shareholders' derivative action was filed against current and former members of our Board of Directors, as well as certain current and former executives in the U.S. District Court for the Northern District of Texas. Fluor is named as a nominal defendant in the action. The action purports to assert claims on behalf of Fluor and makes substantially the same factual allegations as the securities class action matter discussed above and seeks various forms of declaratory and monetary relief, as well as corporate reforms. Three further derivative actions were filed in November and December 2025, all of which are also based on the same factual allegations. In addition, in November 2025, a Fluor shareholder made a Section 220 demand to Fluor for certain books and records. We also intend to contest these derivative claims.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

**12.&nbsp;&nbsp;&nbsp;&nbsp;Contract Assets and Liabilities**

The following summarizes information about our contract assets and liabilities:

---

| | | |
|:---|:---|:---|
| | **December 31,** | **December 31,** |
|<br>**(in millions)** | **2025** | **2024** |
| &nbsp;&nbsp;&nbsp;**Information about contract assets:** |  |  |
| &nbsp;&nbsp;&nbsp;Contract assets |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Unbilled receivables - reimbursable contracts | $1100 | $1050 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Contract work in progress - lump sum contracts | 46 | 88 |
| &nbsp;&nbsp;&nbsp;Contract assets | $1146 | $1138 |
|  | **Year Ended December 31,** | **Year Ended December 31,** |
|  | **2025** | **2024** |
| &nbsp;&nbsp;&nbsp;**Information about contract liabilities:** |  |  |
| &nbsp;&nbsp;&nbsp;Revenue recognized that was included in contract liabilities as of January 1 | $542 | $511 |

---

We periodically evaluate our project forecasts and the amounts recognized with respect to our claims and unapproved change orders. We include estimated amounts for claims and unapproved change orders in project revenue to the extent it is probable we will realize those amounts. As of December 31, 2025 and 2024, we had recorded $214 million and $244 million, respectively, of revenue associated with claims for costs incurred to date. The settlement of these claims, which are included in contract assets and accounts receivable on the balance sheet, may extend beyond one year. Additional costs, which will increase this balance over time, are expected to be incurred in future periods. We had up to $105 million and $23 million of back charges that may be disputed as of December 31, 2025 and 2024, respectively.

**13. Remaining Unsatisfied Performance Obligations**

We estimate that our RUPO will be satisfied over the following periods:

---

| | |
|:---|:---|
| **(in millions)** | **December 31, 2025** |
| Within 1 year | $12047 |
| 1 to 2 years | 6106 |
| Thereafter | 6168 |
| Total RUPO | $24321 |

---

**14.&nbsp;&nbsp;&nbsp;&nbsp;Debt and Letters of Credit**

Debt consisted of the following:

---

| | | |
|:---|:---|:---|
| | **December 31,** | **December 31,** |
|<br>**(in millions)** | **2025** | **2024** |
| Borrowings under credit facility | $— | $— |
| Senior Notes |  |  |
| &nbsp;&nbsp;&nbsp;&nbsp;2028 Notes (4.250% Senior Notes) | $506 | $543 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Unamortized discount and deferred financing costs | (2) | (2) |
| &nbsp;&nbsp;&nbsp;&nbsp;2029 Notes (1.125% Convertible Senior Notes) | 575 | 575 |
| &nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;Unamortized deferred financing costs | (9) | (12) |
| Total debt | $1070 | $1104 |

---

*Credit Facility*

As of December 31, 2025, letters of credit totaling $424 million were outstanding under our $2.2 billion credit facility, which matures in February 2028. The credit facility contains customary financial covenants, including a debt-to-capitalization ratio that cannot exceed 0.60 to 1.00, a limitation on the aggregate amount of debt of the greater of $750 million or €750

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

million for our subsidiaries, and a minimum liquidity threshold of $1.1 billion, all as defined in the amended credit facility, which may be reduced to $1.0 billion upon the repayment of debt. The credit facility also contains provisions that will require us to provide collateral to secure the facility should we be downgraded to BB by S&P and Ba2 by Moody's, such collateral consisting broadly of our U.S. assets. Borrowings under the facility, which may be denominated in USD, EUR, or GBP, bear interest at a base rate, plus an applicable borrowing margin. As of December 31, 2025, we had not made any borrowings under our credit line and maintained a borrowing capacity of $901 million.

*Uncommitted Lines of Credit*

As of December 31, 2025, letters of credit totaling $918 million were outstanding under uncommitted lines of credit.

*2029 Notes*

In August 2023, we issued $575 million of 1.125% Convertible Senior Notes (the "2029 Notes") due August 15, 2029 and received net proceeds of $560 million. Interest on the 2029 Notes is payable semi-annually on February 15 and August 15, beginning on February 15, 2024. The conversion rate for the 2029 Notes is 22.0420 shares of common stock per $1,000 principal amount of notes, which is equivalent to an initial conversion price of $45.37 per share. Holders may convert their 2029 Notes any time before May 2029 under the following conditions:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• if the last reported price of our common stock for at least 20 trading days (whether or not consecutive) during a period of 30 consecutive trading days ending on, and including, the last trading day of the immediately preceding calendar quarter is greater than or equal to $58.98 on each applicable trading day;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• during the 5-business day period after any 5-consecutive trading day period in which the trading price of the 2029 Notes was less than 98% of the product of the last reported stock price and the conversion rate;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• if we call any or all of the 2029 Notes for redemption; or

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• upon the occurrence of specified events as described in the applicable indenture.

In addition, holders may convert their 2029 Notes any time beginning in May 2029 and prior to maturity without regard to the foregoing circumstances. Upon any conversion, we will repay the principal amount of the notes in cash and may elect to convey the conversion premium in any combination of cash and shares of our common stock. Certain events could cause the conversion rate to increase, including a make-whole fundamental change or redemption, but in no event will the conversion rate for a single note exceed 29.2056 shares of our common stock, other than for customary adjustments described in the applicable indenture.

After August 2026, we may elect to redeem up to all of the outstanding 2029 Notes if our common stock has a prevailing per share closing price in excess of $58.98. In such election, all principal would be settled in cash and could result in a make-whole premium if the holders also elect to convert. We may elect to pay any make-whole premium in any combination of cash and shares of our common stock.

*Capped Call Transactions*

In connection with the 2029 Notes offering, we entered into capped call transactions with certain banks. The capped call transactions are not part of the terms of the 2029 Notes and are accounted for as separate transactions. As the capped call options are indexed to our own stock, they are recorded in shareholders' equity and are not accounted for as derivatives. The cost of the capped call transactions was $73 million which was recorded as a permanent reduction to APIC, and is not subject to periodic remeasurement. The strike price of the capped call options corresponds to the conversion price of the 2029 Notes of $45.37 per share. The capped call options are expected to offset potential dilution to our common stock upon conversion of any 2029 Notes and/or offset any cash payments we are required to make for any conversion premium if our stock price is greater than $45.37. The upper limit of the capped calls is $68.48 per share. If our stock price exceeds $68.48, there would be unmitigated dilution and/or no offset of any cash payments attributable to the amount by which our stock exceeds the cap price. We will not be required to make any cash payments to option counterparties upon the exercise of capped call options, but we will be entitled to receive from them shares of our common stock or an amount of cash based on the amount by which the market price of our common stock exceeds the strike price of the capped calls.

*2028 Notes*

In August 2018, we issued $600 million of 4.250% Senior Notes due in September 2028 ("2028 Notes") and received proceeds of $595 million. Interest on the 2028 Notes is payable semi-annually in March and September. Prior to June 2028, we may redeem the 2028 Notes at a redemption price equal to 100% of the principal amount, plus a "make whole" premium

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

described in the indenture. After June 2028, the 2028 Notes can be redeemed at par plus accrued interest. A change of control (as defined by the terms of the indenture) could require us to repay them at 101% of the principal amount, plus accrued interest. We are permitted to incur additional indebtedness if we are in compliance with certain restrictive covenants, including restrictions on liens and restrictions on sale and leaseback transactions. During 2025 and 2024, we redeemed $37 million and $57 million, respectively, of the aggregate outstanding 2028 Notes, with an immaterial earnings impact.

**15. Convertible Preferred Stock**

In September 2023, we exercised our mandatory conversion rights on our CPS in which all of the outstanding shares of CPS converted to 44.9585 shares of our common stock, plus a cash payment of $45.23 per CPS for a make-whole premium of $27 million.

**16.&nbsp;&nbsp;&nbsp;&nbsp;Fair Value Measurements**

The fair value hierarchy prioritizes the use of inputs used in valuation techniques into the following three levels:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Level 1 — quoted prices in active markets for identical assets and liabilities

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Level 2 — inputs other than quoted prices in active markets for identical assets and liabilities that are observable, either directly or indirectly

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;• Level 3 — unobservable inputs

We perform procedures to verify the reasonableness of pricing information received from third parties for significant assets and liabilities classified as Level 2.

The following table delineates assets and liabilities that are measured at fair value on a recurring basis:

---

| | | | | | | | | |
|:---|:---|:---|:---|:---|:---|:---|:---|:---|
| | **December 31, 2025** | **December 31, 2025** | **December 31, 2025** | **December 31, 2025** | **December 31, 2024** | **December 31, 2024** | **December 31, 2024** | **December 31, 2024** |
| | **Fair Value Hierarchy** | **Fair Value Hierarchy** | **Fair Value Hierarchy** | **Fair Value Hierarchy** | **Fair Value Hierarchy** | **Fair Value Hierarchy** | **Fair Value Hierarchy** | **Fair Value Hierarchy** |
|<br>**(in millions)** | **Total** | **Level 1** | **Level 2** | **Level 3** | **Total** | **Level 1** | **Level 2** | **Level 3** |
| Assets: |  |  |  |  |  |  |  |  |
| &nbsp;&nbsp;Investment in NuScale<sup>(1)</sup> | $1579 | $1579 | $— | $— | $2266 | $2266 | $— | $— |
| &nbsp;&nbsp; NuScale forward contract<sup>(2)</sup> | 208 |  | 208 |  |  |  |  |  |
| &nbsp;&nbsp;Trading securities<sup>(3)</sup> | 2 | 2 |  |  | 18 | 18 |  |  |

---

(1)We recognize the fair value of our investment in NuScale on a mark-to-market basis based upon the prevailing price of their stock on our balance sheet dates.

(2)In November 2025, through an indirect, wholly-owned subsidiary, we entered into a variable price forward sale agreement whereby we pledged and granted a security interest in 71 million of our shares in NuScale, while maintaining continuing involvement and ownership rights, and committed to sell, convey, transfer, assign and deliver those shares at the final settlement date in the first quarter of 2026. The fair value of the forward contract, which met the definition of a derivative, represents the difference between the closing price of NuScale at December 31, 2025 and the year-to-date settlement price calculated per the agreement plus a discounted growth assumption through the estimated settlement date. The derivative asset was included in other current assets on the balance sheet as of December 31, 2025.

Certain subsidiaries included in these consolidated financial statements, including Fluor Enterprises, Inc. and Nuke Holdings, LLC, are separate legal entities. The assets of these entities are not available to satisfy the debts or obligation of any other entity, including Fluor and its other subsidiaries.

(3) &nbsp;&nbsp;&nbsp;&nbsp;Consists of registered money market funds and an equity index fund held in deferred compensation trusts. These investments represent the net asset value at the close of business of the period based on the last trade or official close of an active market or exchange.

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

The following summarizes information about financial instruments that are not required to be measured at fair value:

---

| | | | | | |
|:---|:---|:---|:---|:---|:---|
| | | **December 31, 2025** | **December 31, 2025** | **December 31, 2024** | **December 31, 2024** |
|<br>**(in millions)** |<br>**Fair Value Hierarchy** | **Carrying Value** | **Fair Value** | **Carrying Value** | **Fair Value** |
| Assets: |  |  |  |  |  |
| &nbsp;&nbsp;Cash<sup>(1)</sup> | Level 1 | $1480 | $1480 | $1613 | $1613 |
| &nbsp;&nbsp;Cash equivalents<sup>(2)</sup> | Level 2 | 655 | 655 | 1216 | 1216 |
| &nbsp;&nbsp;Marketable securities<sup>(2)</sup> | Level 2 | 59 | 59 | 130 | 130 |
| Liabilities: |  |  |  |  |  |
| &nbsp;&nbsp;2028 Senior Notes<sup>(3)</sup> | Level 2 | $504 | $503 | $541 | $517 |
| &nbsp;&nbsp;2029 Senior Notes<sup>(3)</sup> | Level 2 | 566 | 657 | 563 | 725 |

---

_______________________________________________________________________________

(1)Cash consists of bank deposits. Carrying amounts approximate fair value.

(2)Cash equivalents and marketable securities primarily consist of time deposits. Carrying amounts approximate fair value because of the short-term maturity of these instruments. Amortized cost is not materially different from the fair value.

(3)The fair value of the Senior Notes was estimated based on quoted market prices and Level 2 inputs.

**17.&nbsp;&nbsp;&nbsp;&nbsp;Stock-Based Compensation**

***Equity Awards***

Stock-based compensation expense for equity awards totaled $30 million, $31 million and $48 million during 2025, 2024 and 2023, respectively, with no associated tax benefits. This stock-based compensation primarily related to performance-based award units awarded to our Section 16 officers and also included the amortization of RSU and stock option awards that were less significant.

Performance-based award units totaling 278,193, 272,844 and 274,755 were awarded to most officers, including all Section 16 officers, during 2025, 2024 and 2023, respectively. These awards generally cliff vest after 3 years and contain annual performance conditions for each of the 3 years of the vesting period. Under GAAP, performance-based elements of such awards are not deemed granted until the performance targets have been established. The performance targets for each year are generally established in the first quarter.

For awards granted under the 2025 performance award plan, 70% of the award is earned based on achievement of earnings before taxes targets over three 1-year periods and 30% of the award is earned based on our 3-year cumulative TSR relative to companies in the S&P 500 on the date of the award. For awards granted under the 2024 and 2023 performance plans, 80% of the award is earned based on achievement of earnings before tax targets over three 1-year periods and 20% of the award is earned based on our 3-year cumulative TSR relative to companies in the S&P 500 on the date of the award. The performance component of these awards is deemed granted when targets are set while the TSR component of these awards is deemed granted upon issuance. During the first quarter of 2025, the following units were granted based upon the establishment of performance targets:

---

| | | |
|:---|:---|:---|
| | **Performance-based Award Units Granted in 2025** | **Weighted<br>Average<br>Grant Date<br>Fair Value<br>Per Share** |
| &nbsp;&nbsp;2025 Performance Award Plan | 140597 | $37.07 |
| &nbsp;&nbsp;2024 Performance Award Plan | 68794 | $39.75 |
| &nbsp;&nbsp;2023 Performance Award Plan | 69169 | $39.99 |

---

For awards granted under these performance award plans, the number of units are adjusted at the end of each performance period based on attainment of certain performance targets and on market conditions, pursuant to the terms of the award agreements. As of December 31, 2025, there were 191,810 shares associated with performance awards that had

------

<u>[**Table of Contents**](#i99155b137c484eadafc407f6a8cc1413_7)</u>

**FLUOR CORPORATION**

**NOTES TO FINANCIAL STATEMENTS (Continued)**

been awarded to employees, but which are not deemed granted due to the underlying performance targets having not yet been established.

***Liability Awards***

We grant SGI awards in the form of stock units, determined by dividing the target amount by the closing price of our common stock at the grant date. Each stock unit represents the right to receive cash equal to the value of 1 share of our common stock upon vesting. SGI awards granted to executives vest and become payable at a rate of 1/3 of the total award each year. Performance-based awards were awarded to non-Section 16 executives and will be settled in cash on a single date each year.

---

| | | | | |
|:---|:---|:---|:---|:---|
| | **Location in Statement of Operations** | **December 31,** | **December 31,** | **December 31,** |
|<br>***Compensation Expense (in millions)*** | **Location in Statement of Operations** | **2025** | **2024** | **2023** |
| SGI awards | G&A | $11 | $30 | $34 |
| Performance-based awards for non-Section 16 executives | G&A | 5 | 14 | 21 |

---

---

| | | | |
|:---|:---|:---|:---|
| ***Liabilities (in millions)*** | **Location on Balance Sheet** | **December 31, 2025** | **December 31, 2024** |
| SGI awards | Accrued salaries, wages and benefits and<br>other noncurrent liabilities  | $29 | $51 |
| Performance-based awards for non-Section 16 executives | Accrued salaries, wages and benefits and<br>other noncurrent liabilities | 22 | 30 |

---

**18.&nbsp;&nbsp;&nbsp;&nbsp;Retirement Plans**

*DC Plans*

Domestic and international DC plans are available to eligible salaried and craft employees. Company contributions to DC plans are based on an employee's eligible compensation and participation rate. We recognized expense of $148 million, $145 million and $143 million in 2025, 2024 and 2023, respectively.

*Multiemployer Pension Plans*

We participate in multiemployer pension plans for unionized construction and maintenance craft employees. Company contributions are based on the hours worked by employees covered under various collective bargaining agreements and totaled $38 million, $56 million and $75 million during 2025, 2024 and 2023, respectively. Upon withdrawal from a multiemployer plan, we may have an obligation to make additional contributions for our share of any unfunded benefit obligation, but only if we do not meet the requirements of any applicable exemptions. The preceding information does not include amounts related to benefit plans applicable to employees associated with certain contracts with the U.S. Department of Energy because we are not responsible for the current or future funding of these plans.

**19.&nbsp;&nbsp;&nbsp;&nbsp;Other Noncurrent Liabilities**

We have deferred compensation plans and other retirement arrangements for executives which generally provide for payments upon retirement, death or termination of employment. As of December 31, 2025 and 2024, the obligations related to these plans totaled $240 million and $251 million, respectively, within noncurrent liabilities. To fund these obligations, we have established non-qualified trusts, which are included in noncurrent assets. These trusts hold life insurance policies and marketable securities. These trusts were valued at $221 million as of both December 31, 2025 and 2024. Periodic changes in the value of these trust investments, most of which are unrealized, are recognized in earnings, and serve to mitigate changes to the obligations which are also reflected in earnings.

We maintain appropriate levels of insurance for business risks, including workers compensation and general liability. Insurance coverages contain various retention amounts for which we provide accruals based on the aggregate of the liability for reported claims and an actuarially determined estimated liability for claims incurred but not reported. As of December 31, 2025 and 2024, insurance liabilities of $64 million and $68 million, respectively, were included in noncurrent liabilities.

## Exhibit 10.25

**Exhibit 10.25**

**Summary of Fluor Corporation Non-Management Director Compensation**

**Cash Compensation**

---

| | |
|:---|:---|
| Annual Retainer: | $130000 |
| Annual Committee Chair Retainer: |  |
| Audit Committee Chair: | $25000 |
| Commercial Strategies and Operational Risk Committee Chair: | $20000 |
| Governance Committee Chair: | $20000 |
| Organization and Compensation Committee Chair: | $20000 |
| Lead Independent Director Retainer: | $45000 |
| Non-Committee Chair Member of the Executive Committee: | $10000 |

---

Retainers are paid quarterly in cash and can be deferred at the director's election under the Fluor Corporation 409A Director Deferred Compensation Program (the "Deferred Compensation Program").

**Equity Compensation**

Each non-management director receives an annual grant of restricted stock units with a total market value of $190,000. The grant is made on the date of the annual meeting of shareholders. Non-management directors joining the Board after the date of the annual meeting receive a pro rata award on the date of their appointment to the Board. The restricted stock units vest immediately upon grant. Directors can defer such units at their election under the Deferred Compensation Program.

**Other Information**

Fluor Corporation reimburses non-management directors for their travel and related expenses in connection with attending Board meetings and Board-related activities. Directors also receive life insurance ($75,000 in coverage) and business travel accident insurance ($250,000 in coverage). Directors' charitable contributions that meet the

------

**Exhibit 10.25**

guidelines of the Company's employee charitable matching gift program are eligible for matching funds from the Company in an amount up to $15,000 per year.

## Exhibit 21.1

**Exhibit 21.1**

---

| | | | |
|:---|:---|:---|:---|
| FLUOR CORPORATION SUBSIDIARIES<sup>(1)</sup> | FLUOR CORPORATION SUBSIDIARIES<sup>(1)</sup> | FLUOR CORPORATION SUBSIDIARIES<sup>(1)</sup> | FLUOR CORPORATION SUBSIDIARIES<sup>(1)</sup> |
| [Note: Roman numerals below denote the level of the subsidiary. For example, "I" represents a first tier subsidiary of Fluor Corporation; "II" represents a second tier subsidiary, etc.] | [Note: Roman numerals below denote the level of the subsidiary. For example, "I" represents a first tier subsidiary of Fluor Corporation; "II" represents a second tier subsidiary, etc.] | [Note: Roman numerals below denote the level of the subsidiary. For example, "I" represents a first tier subsidiary of Fluor Corporation; "II" represents a second tier subsidiary, etc.] | [Note: Roman numerals below denote the level of the subsidiary. For example, "I" represents a first tier subsidiary of Fluor Corporation; "II" represents a second tier subsidiary, etc.] |
| **<u>Subsidiary Name</u>** | **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |
| **I** | **American Construction Equipment Company, Inc.** | 100.0000 | California |
| II | AMECO Holdings, Inc. | 100.0000 | California |
|  | AMECO Caribbean, Inc. | 100.0000 | California |
|  | Ameco Services, S. de R.L. de C.V. | 3.0320 | Mexico |
|  | Maquinaria Ameco Guatemala, Limitada | 3.9400 | Guatemala |
| II | Ameco Services, S. de R.L. de C.V. | 24.0990 | Mexico |
| **I** | **Fluor Constructors International, Inc.** | 100.0000 | California |
| II | Fluor Constructors Canada Ltd. | 100.0000 | New Brunswick |
| II | Fluor Management and Technical Services, Inc. | 100.0000 | California |
| II | Servicios de Construccion del Pacifico, Inc. | 100.0000 | Delaware |
| **I** | **Fluor Enterprises, Inc.** | 100.0000 | California |
| II | 202 Maintenance Services, LLC | 50.0000 | Delaware |
| II | AMECODISC, LLC | 100.0000 | Delaware |
|  | AMECO PANAMA S.A. | 100.0000 | Panama |
|  | Ameco Services, S. de R.L. de C.V. | 72.8690 | Mexico |
|  | Maquinaria Ameco Guatemala, Limitada | 95.0800 | Guatemala |
| II | Cavendish Fluor Partnership Limited | 35.0000 | England |
| II | Connect 202 Partners, LLC | 38.0000 | Delaware |
| II | ConOps Industrial Ltd. | 100.0000 | New Brunswick |
| II | Daniel International Corporation | 100.0000 | South Carolina |
|  | Fluor Daniel Engineering, Inc. | 100.0000 | Ohio |
|  | Fluor Management Company L.P. | 46.0676 | Delaware |
| II | Dean / Fluor, LLC | 50.0000 | Delaware |
| II | Denver Transit Constructors, LLC | 40.0000 | Delaware |
| II | Denver Transit Operators, LLC | 50.0000 | Delaware |
| II | Denver Transit Systems, LLC | 50.0000 | Delaware |
| II | EFDEE Connecticut Architects, Inc. | 100.0000 | Connecticut |
|  | Industrial Services France SAS | 100.0000 | France |
| II | EFDEE Engineering Professional Corporation | 100.0000 | North Carolina |
| II | EFDEE Mississippi Architects, A Professional Corporation | 100.0000 | Mississippi |
| II | EFDEE New York Engineers & Architects P.C. | 100.0000 | New York |
| II | ENCEE Architecture Services, P.C. | 100.0000 | North Carolina |
| II | FD Architects & Engineers Corporation | 100.0000 | New Jersey |
| II | FDEE Consulting, Inc. | 100.0000 | California |
| II | FHdB, LLC | 100.0000 | Texas |
| II | Fluor Alaska, Inc. | 100.0000 | Alaska |
| II | Fluor Americas, Inc. | 100.0000 | California |
| II | Fluor Arabia Limited | 50.0000 | Saudia Arabia |
| II | Fluor Australia Pty Ltd. | 100.0000 | Australia |
|  | Fluor Global Services Australia Pty Ltd. | 100.0000 | Australia |
|  | Giovenco Industries (AUST) Pty Limited | 100.0000 | Australia |
|  | Giovenco Industrial Services Pty Ltd. | 100.0000 | Australia |
|  | Giovenco/Insulations International JV Pty Ltd. | 100.0000 | Australia (JV) |
|  | Giovenco/Insulations International JV Unit Trust | 100.0000 | Australia (JV) |
|  | Stork Technical Services Holding Australia Pty Ltd. | 100.0000 | Australia |

---

------

---

| | | |
|:---|:---|:---|
| **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |

---

---

| | | | | | |
|:---|:---|:---|:---|:---|:---|
| | | IV | Giovenco Industries (AUST) Trust | 100.0000 | Australia |
| | III | TRS Staffing Solutions (Australia) Pty Ltd. | TRS Staffing Solutions (Australia) Pty Ltd. | 100.0000 | Australia |
| II | Fluor BNA O&M USA LLC | Fluor BNA O&M USA LLC | Fluor BNA O&M USA LLC | 100.0000 | Delaware |
|  | III | BNA O&M USA General Partnership | BNA O&M USA General Partnership | 40.0000 | Delaware |
| II | Fluor Brasil, Ltda.&nbsp;&nbsp;&nbsp;&nbsp; | Fluor Brasil, Ltda.&nbsp;&nbsp;&nbsp;&nbsp; | Fluor Brasil, Ltda.&nbsp;&nbsp;&nbsp;&nbsp; | 100.0000 | Brazil |
|  | III | Fluor Engenharia e Projetos S.A. | Fluor Engenharia e Projetos S.A. | 99.9900 | Brazil (JV) |
| II | Fluor Canada Ltd. | Fluor Canada Ltd. | Fluor Canada Ltd. | 100.0000 | New Brunswick |
|  | III | BNA CA DFA Inc. | BNA CA DFA Inc. | 40.0000 | Canada |
|  | III | BNA Constructors Canada GP | BNA Constructors Canada GP | 40.0000 | Canada |
|  | III | Fluor Architecture Canada Ltd. | Fluor Architecture Canada Ltd. | 100.0000 | Alberta |
|  | III | Fluor BNA Holdco Inc. | Fluor BNA Holdco Inc. | 100.0000 | New Brunswick |
|  |  | IV | Fluor BNA GP Inc. | 100.0000 | New Brunswick |
|  |  | V | Bridging North America Holding Corporation | 40.0000 | Canada |
|  |  |  | Bridging North America GP (Ontario) | 99.9900 | Canada |
|  |  |  | Bridging North America Holding ULC | 100.0000 | Canada |
|  |  |  | Bridging North America GP (Ontario) | .0100 | Canada |
|  | III | Fluor BNA O&M GP Inc. | Fluor BNA O&M GP Inc. | 100.0000 | New Brunswick |
|  |  | IV | BNA O&M General Partnership | 40.0000 | Canada |
|  | III | Fluor Engineering Solutions Ltd. | Fluor Engineering Solutions Ltd. | 100.0000 | New Brunswick |
|  | III | Fluor O&M Solutions GP Inc. | Fluor O&M Solutions GP Inc. | 100.0000 | New Brunswick |
|  |  | IV | ACS-Fluor O&M Solutions GP | 40.0000 | Ontario |
|  | III | Fluor WEP Holdings Inc. | Fluor WEP Holdings Inc. | 100.0000 | New Brunswick |
|  |  | IV | Windsor Essex Mobility Group GP | 8.3333 | Canada |
|  | III | TRS Staffing Solutions (Canada) Inc. | TRS Staffing Solutions (Canada) Inc. | 100.0000 | New Brunswick |
| II | Fluor Chile, Inc. | Fluor Chile, Inc. | Fluor Chile, Inc. | 100.0000 | California |
|  | III | Fluor Chile Ingenieria y Construccion S.A. | Fluor Chile Ingenieria y Construccion S.A. | 99.0000 | Chile |
|  |  | IV | Fluor Techint SRL Construccion y Servicios Limitada | 50.0000 | Chile |
|  | III | Ingenieria y Construccion Fluor Daniel Chile Limitada | Ingenieria y Construccion Fluor Daniel Chile Limitada | 99.9000 | Chile |
| II | Fluor Colombia Limited | Fluor Colombia Limited | Fluor Colombia Limited | 100.0000 | Delaware |
| II | Fluor Daniel (Japan) Inc. | Fluor Daniel (Japan) Inc. | Fluor Daniel (Japan) Inc. | 100.0000 | Japan |
| II | Fluor Daniel (Malaysia) Sdn. Bhd | Fluor Daniel (Malaysia) Sdn. Bhd | Fluor Daniel (Malaysia) Sdn. Bhd | 100.0000 | Malaysia |
|  | III | Technip-Fluor JV | Technip-Fluor JV | 49.0000 | Malaysia (JV) |
| II | Fluor Daniel Caribbean, Inc. | Fluor Daniel Caribbean, Inc. | Fluor Daniel Caribbean, Inc. | 100.0000 | Delaware |
|  | III | Duke/Fluor Daniel Caribbean S.E. | Duke/Fluor Daniel Caribbean S.E. | 00.2500 | Puerto Rico |
|  | III | Fluor Craft Services, Inc. | Fluor Craft Services, Inc. | 100.0000 | South Carolina |
|  | III | Fluor Daniel International (Malaysia) Sdn. Bhd. | Fluor Daniel International (Malaysia) Sdn. Bhd. | 100.0000 | Malaysia |
|  | III | Fluor Daniel Maintenance Services, Inc. | Fluor Daniel Maintenance Services, Inc. | 100.0000 | Delaware |
|  | III | Fluor Daniel Services Corporation | Fluor Daniel Services Corporation | 100.0000 | Delaware |
|  | III | Fluor Facility & Plant Services, Inc. | Fluor Facility & Plant Services, Inc. | 100.0000 | South Carolina |
| II | Fluor Daniel China Services, Inc. | Fluor Daniel China Services, Inc. | Fluor Daniel China Services, Inc. | 100.0000 | California |
| II | Fluor Daniel Coal Services International, Inc. | Fluor Daniel Coal Services International, Inc. | Fluor Daniel Coal Services International, Inc. | 100.0000 | Delaware |
|  | III | Duke/Fluor Daniel International | Duke/Fluor Daniel International | 49.9999 | Nevada |
|  |  | IV | Duke/Fluor Daniel Caribbean, S.E. | 99.0000 | Puerto Rico |
| II | Fluor Daniel Construction Company | Fluor Daniel Construction Company | Fluor Daniel Construction Company | 100.0000 | California |
| II | Fluor Daniel Development Corporation | Fluor Daniel Development Corporation | Fluor Daniel Development Corporation | 100.0000 | California |
|  | III | FBT Services, Inc. | FBT Services, Inc. | 100.0000 | California |
|  | III | Fluor Daniel Modesto, Inc. | Fluor Daniel Modesto, Inc. | 100.0000 | California |
| II | Fluor Daniel Eastern, Inc. | Fluor Daniel Eastern, Inc. | Fluor Daniel Eastern, Inc. | 100.0000 | California |
|  | III | Fluor Kazakhstan LLC | Fluor Kazakhstan LLC | 100.0000 | Delaware |
|  | III | P.T. Fluor Daniel Indonesia | P.T. Fluor Daniel Indonesia | 80.0000 | Indonesia |
|  |  | IV | PT. Mitra Bersama Engineering | 99.0000 | Indonesia |
| II | Fluor Daniel Engineers & Constructors, Inc. | Fluor Daniel Engineers & Constructors, Inc. | Fluor Daniel Engineers & Constructors, Inc. | 100.0000 | Delaware |
|  | III | Fluor (China) Engineering and Construction Co. Ltd. | Fluor (China) Engineering and Construction Co. Ltd. | 100.0000 | P.R.C. |

---

------

---

| | | |
|:---|:---|:---|
| **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |

---

---

| | | | | |
|:---|:---|:---|:---|:---|
| II | Fluor Daniel Engineers & Constructors, Ltd. | Fluor Daniel Engineers & Constructors, Ltd. | 100.0000 | California |
|  | III | CGF Projects Ghana Limited | 51.0000 | Ghana |
| II | Fluor Daniel Engineers & Consultants Ltd. | Fluor Daniel Engineers & Consultants Ltd. | 100.0000 | Mauritius |
|  | III | Fluor Daniel India Private Limited | 80.0000 | India |
|  | III | Fluor Mocambique, Limitada | 99.0000 | Mozambique |
|  | III | JGC - Fluor Mocambique, Lda | 50.0000 | Mozambique |
|  | III | JGC Fluor TechnipFMC Mocambique, Lda  | 33.3333 | Mozambique |
| II | Fluor Daniel Espana, S.A. | Fluor Daniel Espana, S.A. | 100.0000 | California |
| II | Fluor Daniel Eurasia, Inc. | Fluor Daniel Eurasia, Inc. | 100.0000 | California |
| II | Fluor Engenharia e Projetos S.A. | Fluor Engenharia e Projetos S.A. | 0.0010 | Brazil (JV) |
| II | Fluor Europe B.V. | Fluor Europe B.V. | 100.0000 | Netherlands |
|  | III | AG&P Fluor Joint Venture Company, Inc. | 50.0000 | Philippines (JV) |
|  | III | Fluor B.V. | 100.0000 | Netherlands |
|  |  | Fluor Consultants B.V. | 100.0000 | Netherlands |
|  |  | Fluor Project Services B.V. | 100.0000 | Netherlands |
|  |  | Fluor Infrastructure B.V. | 100.0000 | Netherlands |
|  |  | Fluor A27/A1 B.V. | 100.0000 | Netherlands |
|  |  | Fluor Capital B.V. | 20.0000 | Netherlands |
|  |  | 3Angle B.V. | 33.3333 | Netherlands |
|  |  | IXAS Zuid-Oost B.V. | 25.0000 | Netherlands |
|  |  | Infraspeed (Holdings) B.V. | 3.4800 | Netherlands |
|  |  | IXAS Gaasperdammerweg B.V. | 33.3333 | Netherlands |
|  |  | Fluor Kuwait Company | 49.0000 | Kuwait |
|  |  | Fluor Onshore India Private Limited | 99.9900 | India |
|  |  | Stork Holding B.V. | 100.0000 | Netherlands |
|  |  | Stork B.V. | 100.0000 | Netherlands |
|  |  | SFS 007.298.633 Pty Limited | 100.0000 | Australia |
|  |  | Stork Technical Services HOLDCO B.V. | 100.0000 | Netherlands |
|  |  | Stork Technical Services Holding B.V. | 100.0000 | Netherlands |
|  |  | Stork International B.V. | 100.0000 | Netherlands |
|  |  | Stork Technical Services International Ltd. | 100.0000 | Scotland |
|  |  | Rigblast Energy Services Limited | 100.0000 | Scotland |
|  |  | Stork Technical Services Trinidad and Tobago Ltd | 100.0000 | Trinidad & Tobago |
|  |  | TRS Staffing Solutions B.V. | 100.0000 | Netherlands |
|  | III | Fluor Engineering N.V. | 100.0000 | Belgium |
|  | III | Fluor Island ehf. | 100.0000 | Iceland |
|  | III | Fluor S.A. | 100.0000 | Poland |
|  | III | Fluor Spain Holding S.L. | 4.0000 | Spain |
|  |  | Fluor Plant Engineering, S.A. | 100.0000 | Spain |
|  |  | Technical Resource Solutions, S.L. | 100.0000 | Spain |
|  |  | TRS Staffing Solutions Mozambique, Limitada | 99.0000 | Mozambique |
| II | Fluor Daniel Holdings, Inc. | Fluor Daniel Holdings, Inc. | 100.0000 | California |
|  | III | Fluor Central Asia Limited Liability Partnership | 99.0000 | Kazakhstan |
|  | III | Fluor Daniel Holdings (Botswana) (Pty) Limited | 100.0000 | Botswana |
|  | III | Fluor Daniel Holdings Canada Inc. | 100.0000 | New Brunswick |
|  | III | Fluor Energy Transition Inc. | 100.0000 | Delaware |
|  | III | Fluor Greece S.A. | 100.0000 | Greece |
|  | III | Fluor Investments LLC | 100.0000 | Delaware |
|  | III | Fluor Middle East FZCO | 100.0000 | Dubai, UAE |
|  | III | Fluor Mocambique, Limitada | 1.0000 | Mozambique |
|  | III | Fluor Onshore India Private Limited | 0.0100 | India |
|  | III | Fluor PNG Limited | 100.0000 | Papua New Guinea |
|  | III | Fluor Uganda Engineering and Construction Limited | 99.9999 | Uganda |

---

------

---

| | | |
|:---|:---|:---|
| **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |

---

---

| | | | | | |
|:---|:---|:---|:---|:---|:---|
| | III | FWPJV Limited | FWPJV Limited | 50.0000 | England (JV) |
| | | IV | KPJV Limited | 60.0000 | England (JV) |
| | III | Najmat Al-Sabah for General Services Limited Liability Company, Private Company | Najmat Al-Sabah for General Services Limited Liability Company, Private Company | 100.0000 | Iraq |
| | III | Qatar National Facility Services | Qatar National Facility Services | 49.0000 | Qatar |
| II | Fluor Daniel Illinois, Inc. | Fluor Daniel Illinois, Inc. | Fluor Daniel Illinois, Inc. | 100.0000 | Delaware |
|  | III | D/FD Operating Services LLC | D/FD Operating Services LLC | 49.9999 | Delaware |
| II | Fluor Daniel India, Inc. | Fluor Daniel India, Inc. | Fluor Daniel India, Inc. | 100.0000 | California |
| II | Fluor Daniel Latin America, Inc. | Fluor Daniel Latin America, Inc. | Fluor Daniel Latin America, Inc. | 100.0000 | California |
|  | III | Grupo Empresarial Alvica, S.A. | Grupo Empresarial Alvica, S.A. | 80.0000 | Venezuela |
|  |  | IV | Grupo Alvica SCS | 0.1000 | Venezuela |
| II | Fluor Daniel Mexico S.A. | Fluor Daniel Mexico S.A. | Fluor Daniel Mexico S.A. | 100.0000 | California |
|  | III | ICA Fluor Daniel, S. de R.L. de C.V. | ICA Fluor Daniel, S. de R.L. de C.V. | 49.0000 | Mexico |
|  |  | IV | ICA Fluor Servicios Gerenciales, S.A. de C.V. | 98.0000 | Mexico |
|  |  | V | ICA Fluor Operaciones, S.A. de C.V. | 0.0020 | Mexico |
|  |  | IV | ICA Fluor Operaciones, S.A. de C.V. | 99.9980 | Mexico |
|  |  | V | ICA Fluor Petroquimica S.A. de C.V. | 99.9951 | Mexico |
|  |  |  | Desarrolladora De Etileno, S. de R.L. de C.V. | 20.0000 | Mexico |
|  |  |  | Ethylene XXI Contractors S.A.P.I. | 20.0000 | Mexico |
|  |  |  | Etileno XXI Services B.V. | 20.0000 | Netherlands |
|  |  |  | ICA Fluor Operaciones y Mantenimiento, S. de R.L. de C.V. | 20.0000 | Mexico |
|  |  | V | ICA Fluor Operaciones y Mantenimiento, S. de R.L. de C.V. | 80.0000 | Mexico |
|  |  | IV | ICA Fluor Servicios Operativos, S.A. de C.V. | 90.0000 | Mexico |
|  |  | IV | IF Proyectos, S.A. | 100.0000 | Panama |
|  |  | IV | IFD Servicios de Ingenieria S.A. de C.V. | 98.0000 | Mexico |
|  |  | V | ICA Fluor Servicios Operativos, S.A. de C.V. | 10.0000 | Mexico |
|  |  | V | Industria Del Hierro S.A. de C.V. | 0.0001 | Mexico |
|  |  | V | ICA Fluor Servicios Gerenciales, S.A. de C.V. | 2.0000 | Mexico |
|  |  | IV | Industria Del Hierro S.A. de C.V. | 99.9999 | Mexico |
|  |  | V | ICA Fluor Petroquimica S.A. de C.V. | 0.0049 | Mexico |
|  | III | IFD Servicios de Ingenieria S.A. de C.V. | IFD Servicios de Ingenieria S.A. de C.V. | 0.0200 | Mexico |
|  | III | TRS International Group, S. de R.L. de C.V. | TRS International Group, S. de R.L. de C.V. | 0.9540 | Mexico |
|  | III | TRS Staffing Solutions, S. de R.L. de C.V. | TRS Staffing Solutions, S. de R.L. de C.V. | 0.2000 | Mexico |
| II | Fluor Daniel Mining & Metals, Ltd. | Fluor Daniel Mining & Metals, Ltd. | Fluor Daniel Mining & Metals, Ltd. | 100.0000 | California |
|  | III | Empresa Constructora Fluor Salfa Limitada | Empresa Constructora Fluor Salfa Limitada | 50.0000 | Chile |
|  | III | Fluor Chile Ingenieria y Construccion S.A. | Fluor Chile Ingenieria y Construccion S.A. | 1.0000 | Chile |
|  | III | Ingenieria y Construccion Fluor Daniel Chile Limitada | Ingenieria y Construccion Fluor Daniel Chile Limitada | 0.1000 | Chile |
| II | Fluor Daniel Overseas, Inc. | Fluor Daniel Overseas, Inc. | Fluor Daniel Overseas, Inc. | 100.0000 | California |
|  | III | Fluor Uganda Engineering and Construction Limited | Fluor Uganda Engineering and Construction Limited | 00.0010 | Uganda |
| II | Fluor Daniel P.R.C., Ltd. | Fluor Daniel P.R.C., Ltd. | Fluor Daniel P.R.C., Ltd. | 100.0000 | California |
| II | Fluor Daniel Pacific, Inc. | Fluor Daniel Pacific, Inc. | Fluor Daniel Pacific, Inc. | 100.0000 | California |
| II | Fluor Daniel South America Limited | Fluor Daniel South America Limited | Fluor Daniel South America Limited | 100.0000 | California |
| II | Fluor Daniel Technical Services, Inc. | Fluor Daniel Technical Services, Inc. | Fluor Daniel Technical Services, Inc. | 100.0000 | Texas |
| II | Fluor Daniel Venture Group, Inc. | Fluor Daniel Venture Group, Inc. | Fluor Daniel Venture Group, Inc. | 100.0000 | California |
|  | III | Fluor Daniel Asia, Inc. | Fluor Daniel Asia, Inc. | 100.0000 | California |
|  |  | IV | Duke/Fluor Daniel International Services | 49.9999 | Nevada |
|  |  | V | Duke/Fluor Daniel Caribbean, S.E. | 0.5000 | Puerto Rico |
|  |  | IV | P.T. Fluor Daniel Indonesia | 20.0000 | Indonesia |
|  |  | V | PT. MITRA BERSAMA ENGINEERING | 99.0000 | Indonesia |
|  |  | IV | P.T. Nusantara Power Services | 70.0000 | Indonesia |
|  | III | Soli Flo LLC | Soli Flo LLC | 25.0000 | Delaware |
|  |  | IV | Soli.Flo, Inc. | 100.0000 | California |
| II | Fluor Daniel, a Professional Architectural Corporation | Fluor Daniel, a Professional Architectural Corporation | Fluor Daniel, a Professional Architectural Corporation | 100.0000 | Louisiana |
| II | Fluor Daniel, Inc. - Philippines | Fluor Daniel, Inc. - Philippines | Fluor Daniel, Inc. - Philippines | 99.9900 | Philippines |

---

------

---

| | | |
|:---|:---|:---|
| **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |

---

---

| | | | |
|:---|:---|:---|:---|
| II | Fluor Federal Global Projects, Inc. | 100.0000 | Delaware |
| II | Fluor Federal Services, Inc. | 100.0000 | Washington |
|  | Beyond New Horizons, LLC | 49.0000 | Delaware |
|  | Central Plateau Cleanup Company LLC | 27.0000 | Delaware |
|  | Fluor Federal, Inc. | 100.0000 | Washington |
|  | Fluor Federal Petroleum Operations, LLC | 100.0000 | Delaware |
|  | Fluor Idaho, LLC | 100.0000 | Delaware |
|  | Fluor Marine Propulsion, LLC | 100.0000 | Delaware |
|  | Fluor Mission Solutions Australia Pty Ltd | 100.0000 | Australia |
|  | Worley Fluor Australia Pty Ltd Formed 8/27/24 | 50.0000 | Australia |
|  | Fluor-BWXT Portsmouth LLC | 51.0000 | Ohio |
|  | Four Rivers Nuclear Partnership, LLC | 30.0000 | Delaware |
|  | Hanford Tank Waste Operations & Closure LLC | 14.0000 | Delaware |
|  | Mid-America Conversion Services, LLC | 25.0000 | Delaware |
|  | National Energy Security Operations, LLC | 100.0000 | Delaware |
|  | National TRU Waste Partnership LLC | 55.0000 | Delaware |
|  | Nuclear Production One, LLC | 60.0000 | Delaware |
|  | PanTeXas Deterrence LLC | 37.73 | Delaware |
|  | Precision Drop Zone Logistics, LLC | 100.0000 | Delaware |
|  | Savannah River Mission Completion, LLC | 33.0000 | Delaware |
|  | Savannah River Nuclear Partners, LLC | 57.0000 | Delaware |
|  | Savannah River Nuclear Solutions, LLC | 51.0000 | South Carolina |
|  | Southern Ohio Cleanup Company LLC | 45.5000 | Delaware |
| II | Fluor Federal Services, LLC | 100.0000 | Delaware |
| II | Fluor Federal Solutions, LLC | 100.0000 | South Carolina |
| II | Fluor Fernald, Inc. | 100.0000 | California |
| II | Fluor Finance Limited | 100.0000 | England |
| II | Fluor Finance U.S., Inc. | 100.0000 | Texas |
| II | Fluor GmbH | 100.0000 | Germany |
| II | Fluor Government Group International, Inc. | 100.0000 | Delaware |
| II | Fluor Guinea, Inc. | 100.0000 | Texas |
| II | Fluor Hanford, Inc. | 100.0000 | Washington |
| II | Fluor Heavy Civil, LLC | 100.0000 | Delaware |
| II | Fluor Industrial Services Canada Inc. | 100.0000 | New Brunswick |
| II | Fluor Industrial Services, Inc. | 100.0000 | Delaware |
| II | Fluor Intercontinental, Inc. | 100.0000 | California |
|  | Dominican Republic Combined Cycle, LLC | 49.0000 | Delaware |
|  | Fluor AMEC II, LLC | 100.0000 | Delaware |
|  | Fluor Daniel Nigeria Limited | 60.0000 | Nigeria |
|  | Fluor Government Group-Canada, Inc. | 100.0000 | New Brunswick |
|  | Canadian National Energy Alliance Ltd. | 20.0000 | Canada |
|  | Fluor Intercontinental Germany GmbH | 100.0000 | Germany |
|  | Fluor Intercontinental Solutions, LLC | 100.0000 | Delaware |
|  | FLUOR M ltd. | 100.0000 | Macedonia |
|  | Greenville Technical Services Inc. | 100.0000 | Delaware |
|  | Grupo Alvica SCS | 79.9200 | Venezuela |
|  | NWKC LLC | 50.0000 | Delaware |
| II | Fluor International Limited | 100.0000 | England |
|  | COOEC-Fluor Heavy Industries Co., Ltd. | 49.0000 | China |
|  | Fluor Workforce Solutions Limited | 100.0000 | England |
|  | CSP EG S.L. | 65.0000 | Equatorial Guinea |
|  | Fluor Limited | 100.0000 | England |
|  | Fluor Pension Trustee Limited | 100.0000 | England |

---

------

---

| | | |
|:---|:---|:---|
| **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |

---

---

| | | | | | |
|:---|:---|:---|:---|:---|:---|
| | | IV | FPMM, XXK (FPMM, LLC-English translation) | 100.0000 | Mongolia |
| | III | Fluor Projects Limited | Fluor Projects Limited | 100.0000 | England |
| | III | Kazakh Projects Joint Venture Limited | Kazakh Projects Joint Venture Limited | 50.0000 | England |
| | III | TRS Staffing Solutions Limited | TRS Staffing Solutions Limited | 100.0000 | England |
| II | Fluor International, Inc. | Fluor International, Inc. | Fluor International, Inc. | 100.0000 | California |
|  | III | Fluor Mideast Limited | Fluor Mideast Limited | 100.0000 | California |
|  | III | Iraq Construction Ltd. | Iraq Construction Ltd. | 100.0000 | British Virgin Islands |
|  |  | IV | Iraq Water General Contracting Company L.L.C. | 100.0000 | Iraq |
| II | Fluor Ireland Limited | Fluor Ireland Limited | Fluor Ireland Limited | 100.0000 | Ireland |
|  | III | TRS Staffing Solutions Limited | TRS Staffing Solutions Limited | 100.0000 | Ireland |
| II | Fluor Kazakhstan Inc. | Fluor Kazakhstan Inc. | Fluor Kazakhstan Inc. | 100.0000 | Texas |
|  | III | Fluor Texas, Inc. | Fluor Texas, Inc. | 100.0000 | Texas |
| II | Fluor Maintenance Services, Inc. | Fluor Maintenance Services, Inc. | Fluor Maintenance Services, Inc. | 100.0000 | California |
| II | Fluor Mediterranean, Inc. | Fluor Mediterranean, Inc. | Fluor Mediterranean, Inc. | 100.0000 | California |
| II | Fluor Mining and Metals France, Inc. | Fluor Mining and Metals France, Inc. | Fluor Mining and Metals France, Inc. | 100.0000 | Delaware |
| II | Fluor NE, Inc. | Fluor NE, Inc. | Fluor NE, Inc. | 100.0000 | Arizona |
|  | III | ADP/FD of Nevada, Inc. | ADP/FD of Nevada, Inc. | 100.0000 | Nevada |
| II | Fluor Nuclear Services, Inc. | Fluor Nuclear Services, Inc. | Fluor Nuclear Services, Inc. | 100.0000 | Ohio |
| II | Fluor Oak Ridge, LLC | Fluor Oak Ridge, LLC | Fluor Oak Ridge, LLC | 100.0000 | Delaware |
| II | Fluor Projects, Inc. | Fluor Projects, Inc. | Fluor Projects, Inc. | 100.0000 | Texas |
| II | Fluor Rovuma, Inc. | Fluor Rovuma, Inc. | Fluor Rovuma, Inc. | 100.0000 | Delaware |
| II | Fluor Services International, Inc. | Fluor Services International, Inc. | Fluor Services International, Inc. | 100.0000 | Nevada |
| II | Fluor Spain Holding S.L. | Fluor Spain Holding S.L. | Fluor Spain Holding S.L. | 96.0000 | Spain |
|  | III | Fluor Plant Engineering, S.A. | Fluor Plant Engineering, S.A. | 100.0000 | Spain |
|  | III | Technical Resource Solutions, S.L. | Technical Resource Solutions, S.L. | 100.0000 | Spain |
| II | Fluor Supply Chain Solutions Singapore Pte. Ltd. | Fluor Supply Chain Solutions Singapore Pte. Ltd. | Fluor Supply Chain Solutions Singapore Pte. Ltd. | 100.0000 | Singapore |
| II | Fluor Technologies Corporation | Fluor Technologies Corporation | Fluor Technologies Corporation | 100.0000 | Delaware |
|  | III | KazakhNefteGasServis Limited Liability Partnership | KazakhNefteGasServis Limited Liability Partnership | 50.0000 | Kazakhstan |
| II | Fluor Transworld Services, Inc. | Fluor Transworld Services, Inc. | Fluor Transworld Services, Inc. | 100.0000 | California |
| II | Fluor US Services, Inc. | Fluor US Services, Inc. | Fluor US Services, Inc. | 100.0000 | Delaware |
| II | Fluor-Lane, LLC | Fluor-Lane, LLC | Fluor-Lane, LLC | 65.0000 | Delaware |
| II | Fluor-Lane 95, LLC | Fluor-Lane 95, LLC | Fluor-Lane 95, LLC | 65.0000 | Delaware |
| II | Fluor-Lane South Carolina, LLC | Fluor-Lane South Carolina, LLC | Fluor-Lane South Carolina, LLC | 55.0000 | Delaware |
| II | Fluor-United Asheville, LLC | Fluor-United Asheville, LLC | Fluor-United Asheville, LLC | 60.0000 | Delaware |
| II | Fluor/HDR Global Design Consultants, LLC | Fluor/HDR Global Design Consultants, LLC | Fluor/HDR Global Design Consultants, LLC | 50.0000 | Delaware |
| II | FMC Holding Company LLC | FMC Holding Company LLC | FMC Holding Company LLC | 100.0000 | Delaware |
|  | III | Fluor Management Company L.P. | Fluor Management Company L.P. | 20.5277 | Delaware |
| II | Global Project Execution, Inc. | Global Project Execution, Inc. | Global Project Execution, Inc. | 100.0000 | Delaware |
| II | Goar, Allison & Associates, LLC | Goar, Allison & Associates, LLC | Goar, Allison & Associates, LLC | 100.0000 | Texas |
| II | Indo-Mauritian Affiliates Limited | Indo-Mauritian Affiliates Limited | Indo-Mauritian Affiliates Limited | 100.0000 | Mauritius |
|  | III | Fluor Daniel India Private Limited | Fluor Daniel India Private Limited | 20.0000 | India |
| II | Infrastructure Civil Equipment, LLC | Infrastructure Civil Equipment, LLC | Infrastructure Civil Equipment, LLC | 100.0000 | Delaware |
| II | Integrated Solutions Services, Inc. | Integrated Solutions Services, Inc. | Integrated Solutions Services, Inc. | 100.0000 | California |
| II | LAX Integrated Express Solutions HoldCo, LLC | LAX Integrated Express Solutions HoldCo, LLC | LAX Integrated Express Solutions HoldCo, LLC | 27.0000 | Delaware |
|  | III | LAX Integrated Express Solutions, LLC | LAX Integrated Express Solutions, LLC | 100.0000 | Delaware |
| II | Middle East Fluor | Middle East Fluor | Middle East Fluor | 100.0000 | California |
| II | NuScale Holdings Corp. | NuScale Holdings Corp. | NuScale Holdings Corp. | 76.1875 | Oregon |
| II | P2S Bermuda, LLC | P2S Bermuda, LLC | P2S Bermuda, LLC | 100.0000 | Delaware |
| II | Pegasus Link Constructors, LLC | Pegasus Link Constructors, LLC | Pegasus Link Constructors, LLC | 55.0000 | Delaware |
| II | Plant Engineering Services LLC | Plant Engineering Services LLC | Plant Engineering Services LLC | 100.0000 | Delaware |
| II | Plant Performance Services International LLC | Plant Performance Services International LLC | Plant Performance Services International LLC | 100.0000 | Delaware |
| II | Purple Line Transit Constructors, LLC | Purple Line Transit Constructors, LLC | Purple Line Transit Constructors, LLC | 50.0000 | Delaware |
| II | Servicios Mineria, Inc. | Servicios Mineria, Inc. | Servicios Mineria, Inc. | 100.0000 | Delaware |

---

------

---

| | | |
|:---|:---|:---|
| **<u>Subsidiary Name</u>** | **<u>Percent Holding</u>** | **<u>Organized Under</u>** <br>**<u>Laws of</u>**  |

---

---

| | | | | |
|:---|:---|:---|:---|:---|
| II | Soli-Flo LLC | Soli-Flo LLC | 25.0000 | Delaware |
|  | III | Soli.Flo, Inc. | 100.0000 | Delaware |
| II | Strategic Organizational Systems Enterprises, Inc. | Strategic Organizational Systems Enterprises, Inc. | 100.0000 | California |
| II | Stork USA, Inc. | Stork USA, Inc. | 100.0000 | Delaware |
| II | Support Services International, LLC | Support Services International, LLC | 100.0000 | South Carolina |
| II | Tappan Zee Constructors, LLC | Tappan Zee Constructors, LLC | 30.0000 | Delaware |
| II | TDF Inc. | TDF Inc. | 100.0000 | California |
|  | III | Fluor Daniel Engineers S.A. (Pty) Limited | 100.0000 | Liechtenstein |
|  |  | Trans-Africa Projects Ltd. | 50.0000 | Mauritius |
|  |  | Trans-Africa Projects (Pty) Ltd. | 50.0000 | South Africa |
|  | III | Fluor S.A. (Pty) Limited | 100.0000 | Liechtenstein |
|  |  | Fluor South Africa Proprietary Limited | 90.0000 | South Africa |
|  |  | TRS Staffing Solutions (Pty) Ltd | 100.0000 | South Africa |
|  |  | Fluor-Igoda Projects (Proprietary) Limited | 100.0000 | South Africa |
| II | Venezco, Inc. | Venezco, Inc. | 100.0000 | California |
| II  | Virta Inc. | Virta Inc. | 100.0000 | Delaware |
|  | III | Virta Chile SpA | 100.0000 | Chile |
| II | Williams Brothers Engineering Company | Williams Brothers Engineering Company | 100.0000 | Delaware |
|  | III | Fluor Argentina, Inc. | 100.0000 | Delaware |
| II | WODECO Nigeria Limited | WODECO Nigeria Limited | 60.0000 | Nigeria |
| **I** | **Fluor Holding Company LLC** | **Fluor Holding Company LLC** | 100.0000 | Delaware |
| II | Fluor Management Company L.P. | Fluor Management Company L.P. | 33.4047 | Delaware |
| II | Mineral Resource Development Corporation | Mineral Resource Development Corporation | 100.0000 | Delaware |
|  | III | St. Joe Participacoes Ltda. | 0.0125 | Brazil |
| II | St. Joe Participacoes Ltda | St. Joe Participacoes Ltda | 99.9875 | Brazil |
| **I** | **TRS Staffing Solutions, Inc.** | **TRS Staffing Solutions, Inc.** | 100.0000 | South Carolina |
| II | Agensi Pekerjaan TRS Malaysia SDN. BHD. | Agensi Pekerjaan TRS Malaysia SDN. BHD. | 49.00 | Malaysia |
| II | TRS Craft Services, Inc. | TRS Craft Services, Inc. | 100.0000 | Delaware |
| II | TRS FAR EAST SDN. BHD. | TRS FAR EAST SDN. BHD. | 100.0000 | Malaysia |
|  | III | Agensi Pekerjaan TRS Malaysia SDN. BHD. | 51.0000 | Malaysia |
| II | TRS International Group, S. de R.L. de C.V. | TRS International Group, S. de R.L. de C.V. | 99.0460 | Mexico |
| II | TRS International Payroll Co. | TRS International Payroll Co. | 100.0000 | Texas |
|  | III | TRS Staffing Solutions India Private Limited | 0.1000 | India |
| II | TRS SA HOLDING COMPANY (PTY) LTD | TRS SA HOLDING COMPANY (PTY) LTD | 100.0000 | South Africa |
|  | III | TRS SEARCH AND SELECTION (Pty) Ltd | 100.0000 | South Africa |
| II | TRS STAFFING SOLUTIONS (PROPRIETARY) LIMITED | TRS STAFFING SOLUTIONS (PROPRIETARY) LIMITED | 100.0000 | Botswana |
| II | TRS Staffing Solutions Belgium BV | TRS Staffing Solutions Belgium BV | 100.0000 | Belgium |
| II | TRS Staffing Solutions GmbH | TRS Staffing Solutions GmbH | 100.0000 | Germany |
| II | TRS Staffing Solutions India Private Limited | TRS Staffing Solutions India Private Limited | 99.9000 | India |
| II | TRS Staffing Solutions Mozambique, Limitada | TRS Staffing Solutions Mozambique, Limitada | 1.0000 | Mozambique |
| II | TRS Staffing Solutions (Pty) Ltd | TRS Staffing Solutions (Pty) Ltd | 100.0000 | Botswana |
| II | TRS Staffing Solutions, S. de R.L. de C.V. | TRS Staffing Solutions, S. de R.L. de C.V. | 99.8000 | Mexico |
| <sup>(1)</sup> Does not include certain subsidiaries which if considered in the aggregate as a single subsidiary would not constitute a significant subsidiary | <sup>(1)</sup> Does not include certain subsidiaries which if considered in the aggregate as a single subsidiary would not constitute a significant subsidiary | <sup>(1)</sup> Does not include certain subsidiaries which if considered in the aggregate as a single subsidiary would not constitute a significant subsidiary | <sup>(1)</sup> Does not include certain subsidiaries which if considered in the aggregate as a single subsidiary would not constitute a significant subsidiary | <sup>(1)</sup> Does not include certain subsidiaries which if considered in the aggregate as a single subsidiary would not constitute a significant subsidiary |

---

## Exhibit 23.1

**Exhibit 23.1**

**Consent of Independent Registered Public Accounting Firm**

We consent to the incorporation by reference in the following Registration Statements:

1)Registration Statement (Form S-8 No. 333-148269) pertaining to the Fluor 409A Executive Deferred Compensation Program,

2)Registration Statement (Form S-8 No. 333-148270) pertaining to the Fluor Corporation 409A Deferred Directors' Fees Program,

3)Registration Statement (Form S-8 No. 333-188379) and Post-Effective Amendment No. 1 thereto, pertaining to the Fluor Corporation Amended and Restated 2008 Executive Performance Incentive Plan,

4)Registration Statement (Form S-8 No. 333-217653) pertaining to the Fluor Corporation 2017 Performance Incentive Plan,

5)Registration Statement (Form S-8 No. 333-226546) pertaining to the Fluor Corporation 409A Executive Deferred Compensation Program,

6)Registration Statement (Form S-8 No. 333-251426) pertaining to the Fluor Corporation 2020 Performance Incentive Plan,

7)Registration Statement (Form S-8 No. 333-260823) pertaining to Executive Officer Inducement Awards, and

8)Registration Statement (Form S-3 No. 333-285023) and related Prospectus of Fluor Corporation pertaining to the registration of its debt securities, common stock, preferred stock, depositary shares, warrants, purchase contracts and units;

of our reports dated February 17, 2026, with respect to the consolidated financial statements of Fluor Corporation and the effectiveness of internal control over financial reporting of Fluor Corporation included in this Annual Report (Form 10-K) of Fluor Corporation for the year ended December 31, 2025.

/s/ Ernst & Young LLP

Dallas, Texas

February 17, 2026

## Exhibit 31.1

**Exhibit 31.1**

**CERTIFICATION OF CHIEF EXECUTIVE OFFICER**

**PURSUANT TO RULE 13a-14(a) OR RULE 15d-14(a)**

**OF THE SECURITIES EXCHANGE ACT OF 1934**

I, James R. Breuer, certify that:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;1.&nbsp;&nbsp;&nbsp;&nbsp;I have reviewed this annual report on Form 10-K of Fluor Corporation;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;2.&nbsp;&nbsp;&nbsp;&nbsp;Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;3.&nbsp;&nbsp;&nbsp;&nbsp;Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;4.&nbsp;&nbsp;&nbsp;&nbsp;The registrant's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant and have:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;a)&nbsp;&nbsp;&nbsp;&nbsp;Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;b)&nbsp;&nbsp;&nbsp;&nbsp;Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;c)&nbsp;&nbsp;&nbsp;&nbsp;Evaluated the effectiveness of the registrant's disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;d)&nbsp;&nbsp;&nbsp;&nbsp;Disclosed in this report any change in the registrant's internal control over financial reporting that occurred during the registrant's most recent fiscal quarter (the registrant's fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant's internal control over financial reporting; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;5.&nbsp;&nbsp;&nbsp;&nbsp;The registrant's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant's auditors and the audit committee of the registrant's board of directors (or persons performing the equivalent functions):

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;a)&nbsp;&nbsp;&nbsp;&nbsp;All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant's ability to record, process, summarize and report financial information; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;b)&nbsp;&nbsp;&nbsp;&nbsp;Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant's internal control over financial reporting.

---

| | | |
|:---|:---|:---|
| February 17, 2026 | By: | /s/ James R. Breuer |
|  |  | James R. Breuer |
|  |  | *Chief Executive Officer* |

---

## Exhibit 31.2

**Exhibit 31.2**

**CERTIFICATION OF CHIEF FINANCIAL OFFICER**

**PURSUANT TO RULE 13a-14(a) OR RULE 15d-14(a)**

**OF THE SECURITIES EXCHANGE ACT OF 1934**

I, John C. Regan, certify that:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;1. &nbsp;&nbsp;&nbsp;&nbsp;I have reviewed this annual report on Form 10-K of Fluor Corporation;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;2.&nbsp;&nbsp;&nbsp;&nbsp;Based on my knowledge, this report does not contain any untrue statement of a material fact or omit to state a material fact necessary to make the statements made, in light of the circumstances under which such statements were made, not misleading with respect to the period covered by this report;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;3.&nbsp;&nbsp;&nbsp;&nbsp;Based on my knowledge, the financial statements, and other financial information included in this report, fairly present in all material respects the financial condition, results of operations and cash flows of the registrant as of, and for, the periods presented in this report;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;4.&nbsp;&nbsp;&nbsp;&nbsp;The registrant's other certifying officer(s) and I are responsible for establishing and maintaining disclosure controls and procedures (as defined in Exchange Act Rules 13a-15(e) and 15d-15(e)) and internal control over financial reporting (as defined in Exchange Act Rules 13a-15(f) and 15d-15(f)) for the registrant and have:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;a)&nbsp;&nbsp;&nbsp;&nbsp;Designed such disclosure controls and procedures, or caused such disclosure controls and procedures to be designed under our supervision, to ensure that material information relating to the registrant, including its consolidated subsidiaries, is made known to us by others within those entities, particularly during the period in which this report is being prepared;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;b)&nbsp;&nbsp;&nbsp;&nbsp;Designed such internal control over financial reporting, or caused such internal control over financial reporting to be designed under our supervision, to provide reasonable assurance regarding the reliability of financial reporting and the preparation of financial statements for external purposes in accordance with generally accepted accounting principles;

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;c)&nbsp;&nbsp;&nbsp;&nbsp;Evaluated the effectiveness of the registrant's disclosure controls and procedures and presented in this report our conclusions about the effectiveness of the disclosure controls and procedures, as of the end of the period covered by this report based on such evaluation; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;d)&nbsp;&nbsp;&nbsp;&nbsp;Disclosed in this report any change in the registrant's internal control over financial reporting that occurred during the registrant's most recent fiscal quarter (the registrant's fourth fiscal quarter in the case of an annual report) that has materially affected, or is reasonably likely to materially affect, the registrant's internal control over financial reporting; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;5.&nbsp;&nbsp;&nbsp;&nbsp;The registrant's other certifying officer(s) and I have disclosed, based on our most recent evaluation of internal control over financial reporting, to the registrant's auditors and the audit committee of the registrant's board of directors (or persons performing the equivalent functions):

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;a)&nbsp;&nbsp;&nbsp;&nbsp;All significant deficiencies and material weaknesses in the design or operation of internal control over financial reporting which are reasonably likely to adversely affect the registrant's ability to record, process, summarize and report financial information; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;b)&nbsp;&nbsp;&nbsp;&nbsp;Any fraud, whether or not material, that involves management or other employees who have a significant role in the registrant's internal control over financial reporting.

---

| | | |
|:---|:---|:---|
| February 17, 2026 | By: | /s/ John C. Regan |
|  |  | John C. Regan |
|  |  | *Chief Financial Officer* |

---

## Exhibit 32.1

**Exhibit 32.1**

**CERTIFICATION OF CHIEF EXECUTIVE OFFICER**

**PURSUANT TO RULE 13a-14(b) OR RULE 15d-14(b)**

**OF THE SECURITIES EXCHANGE ACT OF 1934**

**AND 18 U.S.C. SECTION 1350**

In connection with the Annual Report of Fluor Corporation (the "Company") on Form 10-K for the period ended

December 31, 2025, as filed with the Securities and Exchange Commission on the date hereof (the "Report"), I, James R. Breuer, Chief Executive Officer of the Company, certify, for purposes of 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to my knowledge:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;•&nbsp;&nbsp;&nbsp;&nbsp;the Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934, as amended; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;•&nbsp;&nbsp;&nbsp;&nbsp;the information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

---

| | | |
|:---|:---|:---|
| February 17, 2026 | By: | /s/ James R. Breuer |
|  |  | James R. Breuer |
|  |  | *Chief Executive Officer* |

---

*A signed original of this written statement required by 18 U.S.C. Section 1350 has been provided to the Company and will be retained by the Company and furnished to the Securities and Exchange Commission or its staff upon request.*

## Exhibit 32.2

**Exhibit 32.2**

**CERTIFICATION OF CHIEF FINANCIAL OFFICER**

**PURSUANT TO RULE 13a-14(b) OR RULE 15d-14(b)**

**OF THE SECURITIES EXCHANGE ACT OF 1934**

**AND 18 U.S.C. SECTION 1350**

In connection with the Annual Report of Fluor Corporation (the "Company") on Form 10-K for the period ended December 31, 2025, as filed with the Securities and Exchange Commission on the date hereof (the "Report"), I, John C. Regan, Chief Financial Officer of the Company, certify, for purposes of 18 U.S.C. Section 1350, as adopted pursuant to Section 906 of the Sarbanes-Oxley Act of 2002, that to my knowledge:

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;•&nbsp;&nbsp;&nbsp;&nbsp;the Report fully complies with the requirements of Section 13(a) or 15(d) of the Securities Exchange Act of 1934, as amended; and

&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;&nbsp;•&nbsp;&nbsp;&nbsp;&nbsp;the information contained in the Report fairly presents, in all material respects, the financial condition and results of operations of the Company.

---

| | | |
|:---|:---|:---|
| February 17, 2026 | By: | /s/ John C. Regan |
|  |  | John C. Regan |
|  |  | *Chief Financial Officer* |

---

*A signed original of this written statement required by 18 U.S.C. Section 1350 has been provided to the Company and will be retained by the Company and furnished to the Securities and Exchange Commission or its staff upon request.*

## Exhibit 95.1

**Exhibit 95.1**

**Mine Safety Disclosures**

The following disclosures relate only to the Kosse Strip mine (the "Mine") and reflect citations and orders issued to the company by the Federal Mine Safety and Health Administration ("MSHA") during the year ended December 31, 2025. Fluor does not act as the owner of the Mine, but may act as an "operator" as defined under the Federal Mine Safety and Health Act of 1977 where Fluor performs services or construction as an independent contractor at the Mine. The proposed assessments for the year ended December 31, 2025 were taken from the MSHA data retrieval system as of January 5, 2026.

During the year ended December 31, 2025, the MHSA proposed assessments totaling $319. The company instituted two legal actions and resolved four legal actions before the Federal Mine Safety and Health Review Commission ("Review Commission"). Two legal actions were pending before the Review Commission as of December 31, 2025.

The company has no other disclosures to report under Section 1503 for the period covered by this report.

<br>