THE HONOURABLE SRI JUSTICE P.S.NARAYANA THURSDAY, THE TWENTY SEVENTH DAY OF AUGUST, TWO THOUSAND AND NINE WRIT PETITION No. 14887 Of 2009 Between: G.Obul Reddy …Petitioner A N D The Chief Engineer (PR) S.R.T.G.N.Bhavan, Errum-Manzil Colony, Hyderabad and others. …Respondents THE HONOURABLE SRI JUSTICE P.S.NARAYANA WRIT PETITION No. 14887 Of 2009 ORDER: The matter is coming up for admission. 2. On 24-7-2009 learned Additional Government Pleader for Panchayat Raj took time to get instructions and subsequent thereto the matter was adjourned on couple of occasions. 3. This writ petition is filed for a writ of mandamus declaring the action of the respondents in not handing over the site relating to the work APVII/1449 ( @ K.M. 2/0 of UG Road to Gangireddypalli) after entering into the Agreement dated 31-10-2008 to the petitioner is highly arbitrary, bad and illegal and pass such other suitable orders. 4. It is stated that 1st respondent issued notice inviting Tenders NIT. No.321/2008-09 dated 29-8-2009 from the eligible and approved contractors for execution of work relating to construction/up gradation of road K.M. 2/0 from Udayagiri Road to Gangireddypalli under PMGSY Scheme. Further it is averred that the Tenders were received from 18-9-2008 to 4-10-2008 and Financial bids opened on 8-10- 2008. It is also stated that the second respondent entered into agreement with the petitioner on 31-10-2008 for the execution and completion of the work. It is stated that the petitioner has given written application on 12-2-2009 to the second respondent and also to other respondents to hand over the site to commence same and complete the work. It is also stated that the petitioner has given another application on 27-2-2009 to the first respondent and also submitted copies of representations to other respondents requesting to hand over the site. It is further stated that the petitioner has given another representation on 5-6-2009 and 9-7-2009 requesting the respondents to hand over the site as the nine months period is expiring by end of July, 2009. In such circumstances, the writ petitioner approached this Court. 5. Learned Additional Government Pleader for Panchayath Raj states that if the petitioner is prepared to co-operate with the technical team, further steps would be taken in this regard. 6. In the light of the same, let the petitioner approach the 3rd respondent and show his readiness along with the technical team as may be directed by the 3rd respondent and let the third respondent take further steps in this regard in accordance with law. 7. With the above direction, the writ petition is disposed of. No order as to costs. _____________________ Justice P.S.Narayana 27th August, 2009. KM THE HONOURABLE SRI JUSTICE P.S.NARAYANA WRIT PETITION No. 14887 Of 2009 27th August, 2009.