Case ID: ad_167/html/0042-01.html
Source: Caselaw Access Project
Author: {"author": "Per Curiam:", "license": "Public Domain", "url": "https://static.case.law/"}
Date Created: 2024-08-24T03:29:51.129683

Ernest J. Bailey, Respondent, v. Elm City Lumber Company, Appellant.
    Fourth Department,
    March 26, 1915.
    . Sale — action for breach of contract for sale and delivery of lumber — frequent requests for shipment and excuses for delay—effect of cancellation of portion of order, with consent of vendor—waiver of claim for damages.
    In an action for the breach of a contract for the sale of lumber which was to be shipped as soon as possible, providing cars could be secured and unavoidable delays were not encountered, it appeared that there were frequent demands for shipment by the plaintiff, and excuses for delay on the part of the defendant, until the defendant, by letter, definitely stated that shipment could not be completed for some time, and offered the plaintiff the option of canceling the contract. He canceled a portion of his order.
    
      Held, that the plaintiff by accepting the option and canceling a portion of his order waived all claims for damages up to that time and made a new contract;
    That, therefore, a judgment for damages occasioned through a breach of the original contract upon which the action is brought should be reversed.
    
      It seems, that the repeated and continued requests for delivery after a breach by the defendant in that particular are not a bar to all claims for damages for delay, although sufficient to bar the plaintiff’s right to refuse to receive the lumber at a later date.
    Appeal by the defendant, Elm City Lumber Company, from a judgment of the Supreme Court in favor of the plaintiff, entered in the office of the clerk of the county of Chautauqua on the 24th day of January, 1914, upon the decision of the court, a jury having been waived.
    
      James L. Weeks, for the appellant.
    
      William S. Stearns, for the respondent.
   Per Curiam:

The action is for breach of contract in the sale and delivery of a quantity of lumber which the defendant agreed to sell and to deliver to the plaintiff at Westfield, N. Y.

Plaintiff resides at Brocton, N. Y., and the defendant is a corporation at Newbern, N. C. The order for this lumber was placed in April, 1911, and required immediate shipment thereof.

Its receipt was acknowledged April 24, 1911, and the acknowledgment contained a recital that shipment would be made “in about as soon as possible, providing cars can be secured and providing we do not encounter unavoidable delays.”

From then on until June 15, 1911, the record discloses frequent demands for shipment on the part of plaintiff and as frequent excuses for delay on the part of the defendant. On June fifteenth the defendant by letter definitely stated that shipment could not be completed short of thirty or forty days and could not be commenced for ten days or two weeks and offered the plaintiff the option of canceling the order, if he desired.

On June 21, 1911, the plaintiff replied to this communication accepting the right of cancellation in part and canceling a portion of his prior order.

Here then was a new contractual situation between the parties.

The subject of the contract was varied, a new time for delivery was selected and the transaction amounted to a waiver and satisfaction of all claims by the plaintiff, up to that time, for damages for delay in shipment theretofore. (Rice, Barton & Fales M. & I. Co. v. Hoffman- Youmans Paper Mills, 158 App. Div. 309.)

From that time on again, the record contains frequent appeals for shipment by plaintiff, and as frequent excuses and promises on the part of the defendant.

Ho doubt upon a breach occurring following the contratc consummated by plaintiff’s letter of June twenty-first the plaintiff had the right at his election to terminate the contract and sue for his damages both for delay and for additional expense to him by his having to purchase elsewhere.

He did not exercise this option, however, but continued to appeal for and demand shipment in all of his communications to the defendant which appear in this record. Eventually from Chicago, on July 10, 1911, the plaintiff wired defendant asking when the balance of the order could be shipped, and to' that wire the defendant replied promising to ship one car that week, two the next week, and the balance the third week, barring unforeseen delays.

Eventually, and on July 21, 1911, plaintiff wrote his last letter to defendant asking it to hurry along the material on this shipment.

On its arrival at the point of delivery plaintiff refused to accept the delivery, and levied an attachment upon that portion of the lumber delivered, by means of which attachment he obtained jurisdiction to enforce the lien secured thereby. Later the defendant appeared in the action and served an answer.

Plaintiff has had judgment as for damages occasioned through the breach of the original contract made in April, 1911. That judgment cannot stand. As above pointed out, a new contract was made in June, which, as a matter of law, satisfied and extinguished all claims for damages up to that time. In no event could plaintiff recover any damages for delay preceding the making of that new contract.

We cannot, however, accede to defendant’s contention that the repeated and continued requests for delivery after a breach by the defendant in that particular bar all claim for damages in this case. Probably such are sufficient to bar the right of the plaintiff to refuse to receive this lumber at a later date than that contracted for, but such request is a waiver as to delivery only to the time the request was made and such extension of time of delivery does not necessarily conclude plaintiff in his claim for damages for delay. (Rice, Barton & Fales M. & I. Co. v. Hoffman- Youmans Paper Mills, 158 App. Div. 309; Beyer v. Huber Co., 115 id. 342; Reading Hardware Co. v. City of New York, 129 id. 292; Parke v. F. A. T. Co., 120 N. Y. 51.)

It may be that plaintiff has a right to recover damages in some amount against the defendant by reason of defendant’s failure to comply promptly with its obligation to ship, and its renewed and continued failures in that respect, after its many and repeated promises made from time to time. Such a recovery, however, we cannot adjust upon this record in case it can be permitted at all.

The theory of the action as indicated by the complaint is a breach of the original contract. That contract was eliminated and extinguished and a new one substituted therefor. The pleadings do not fit the proofs in this case. There has been a failure of proof on the part of the plaintiff in establishing a breach of contract upon which he has sued. This conclusion dispenses with the necessity of determining the question raised by the defendant as to the effect of the continued and repeated requests for shipment after breach by defendant. Defendant has insisted that such continued requests from plaintiff were waivers of the time element of this contract. Plaintiff has contended that that defense was not available through lack of pleading in the answer.

However that may be, there is a clear failure of proof of the breach of contract sued upon and for which a recovery has been allowed.

Our attention has been directed to many findings which we should feel constrained to criticise, and in some particulars modify, were it not that this case must be reversed. Such reversal dispenses with that necessity.

The case is reversed and a new trial ordered herein, with costs to the appellant to abide the event.

All concurred; Lambert, J., not sitting.

Judgment reversed and new trial granted upon questions of law and fact, with costs to the appellant to abide event.