Case ID: ill-app_217/html/0666-03.html
Source: Caselaw Access Project
Author: {"author": "Mr. Justice Eldredge", "license": "Public Domain", "url": "https://static.case.law/"}
Date Created: 2024-08-24T03:29:51.129683

Joseph Schingle, Jr., appellee, v. M. S. & A. E. Plaut, executors of last will of S. Plaut, deceased, appellants.
    Action to recover balance due on a building contract, deducted as a penalty for delay due to strike. Judgment for -plaintiff. Appeal from the Circuit Court of Vermilion county; the Hon. John H. Marshall, Judge, presiding. Heard in this court at the October term, 1919.
    Reversed with finding of fact.
    Opinion filed April 27, 1920.
    Swallow & Bookwalter, for appellants.
    F. L. Draper and C. R. Shannon, for appellee.
   Mr. Justice Eldredge

delivered the opinion of the court.