Case ID: ny-st-rep_3/html/0501-01.html
Source: Caselaw Access Project
Author: {"author": "Haight, J.", "license": "Public Domain", "url": "https://static.case.law/"}
Date Created: 2024-08-24T03:29:51.129683

William T. Eaton et al., Appl’t, v. The Allegany Gas Company, Limited, et al., Resp’ts.
    
      (Supreme Court, General Term, Fifth Department,
    
    
      Filed October 22, 1886.)
    
    Contract—Lease—Covenants when void because essential parts left blank.
    A peculiar lease of lands with privilege of boring and mining for oil and gas construed, and, held, that a covenant in a lease in the vital and essential parts of which blanks appear, is void for uncertainty.
    Appeal from a judgment entered in Allegany county upon the report of a referee.
    
      Rufus Scott and Hamilton Ward, for appl’ts; Cary & Bumsey, for resp’ts.
   Haight, J.

This action was brought to restrain the defendants from interfering with and to their own use a gas well and the gas therein belonging to the plaintiffs. The referee has found as facts that on the 19th of May, 1881, the defendant, Harvey 0. Foster, leased to the plaintiffs fifteen acres of land, situated in the town of Wirt, Allegany county, “the right to take, bore and mine for and gather all oil or gases found in and upon the premises, to have and to hold the same for the term of twelve years from this date, or as long as oil is found in paying quantities.” In consideration thereof the plaintiffs agreed to give the defendant Foster one-eighth part of the oil produced and saved from the premises. The lease contamed the following covenants:' “The party of the second part covenants to commence operations for said mining purposes, and prosecute the same on some portion of the above described premises within two years from this date, or thereafter pay to the party of the first part dollars per until work is commenced. This lease shall be null and void and at an end, unless said second party shall, within six months from this date, commence and prosecute with due diligence, unavoidable accidents excepted, the sinking and boring of one well on or in the vicinity of this lease to a depth of 1,200 feet unless oil in paying quantities is sooner found. * * * If the party of the second part fails to keep and perform the covenants and agreements by him to he kept and performed, then this lease shall be null and void and surrendered to the party of the first part.” That the defendant Harvey C. Foster was the owner in fee of the premises; that the lessees did, within six months from the date of the lease, commence and prosecute with due diligence, unavoidable accidents excepted, the sinking and boring of one well on the lease to a depth of over 1,200 feet; that for that purpose they entered upon the premises; erected thereon a derrick and engine house, and with their engine, boiler, tools and machinery placed therein by them, commenced drilling the fore part of the month of June, 1881, and first drilled to the depth of 1,093 feet, and after shutting down for about two weeks during the month of July, started up again and drilled to the depth of 1,500 feet, which depth was reached about the middle of the month of August, 1881; that drilling was then suspended_ and after-wards resumed, and in the winter and early spring of .1882 the well was put down 300 feet deeper, malting the total depth of the well 1,800 feet, at an expense to the plaintiffs of about $3,000; that at the depth of 1,045 feet natural gas was found in large quantities, and. at 1,093 feet some oil was found, not, however, in paying quantities; that the well was cased down to the rock a depth of 285 feet, but was never tubed for the purpose of obtaining oil; that the plaintiffs used the gas for fuel in drilling the last 300 feet, but did not utilize the gas in any other manner, the same being thereafter allowed to burn and go to waste; that the plaintiffs did not, after the spring of 1882, further prosecute operations for mining purposes on the premises or thereafter attempt to obtain off on the premises; that in the fall of 1882 the plaintiffs removed their engines, boiler apd machinery from the premises, leaving thereon their derrick and engine house, the casing in the well, and 150 feet of tubing which conducted the gas away from the well; that in the fall of 1883 two or three joints of tubing of the length of about nineteen feet each were taken to the well by the direction of one of the plaintiffs,, but nothing was done with them there.

The referee further found as facts, that on or about the 8th day of February, 1884, the defendant, Foster, by an instrument in writing, let unto the defendant, Charles P. Thurstone, the premises described in the complaint, for the sole purpose of mining, drilling and excavating for petroleum, rock or carbon oil, or gas, or other valuable minerals, containing the following provision: “It is further agreed that this instrument is subject to a lease of a part of said land made to Wilcox, Wheeler & Eaton, in case the same is not now or does not become forfeited or cancelled, and if the well on said lease is used by the said party of the second part, he is to pay the party of the first part rent for the same as if he had drilled it originally.” This lease was subsequently assigned to the defendant, the Allegany Gas Company (limited), who subsequently entered into possession of the premises, took possession of this well, and have ever since appropriated the gas therefrom, conducting it in pipes to the works of the company; that the well and gas have been and are of great value; that after the Allegany Gas Company entered into possession of the premises the plaintiffs, on the 14th day of February, 1884, demanded of the company the right to enter the premises for the purpose of receiving their share of the gas taken from the well; that they were excluded from the well and from any share in the gas by the defendant, the Allegany Gas Company (limited).

The referee further found as conclusions of law, that the suspension of work upon the premises by the plaintiffs and their neglect to prosecute the same from the spring of 1882 to the time of their demand gave to the defendant, Harvey C. Foster, and his assigns, the right to declare the plaintiffs’ rights under the lease forfeited; that the demise by Foster to Thurstone, and the possession so taken under his lease, operated as an election by Foster and his assigns to declare the plaintiff’s lease forfeited for such failure, and the defendants were entitled to have the complaint dismissed, with costs.

The question thus presented depends upon the construction which should be given to the covenants contained in the plaintiffs’ lease. Have the plaintiffs failed to keep and perform the covenants and agreements by them to be kept and performed so as to have forfeited the lease? The referee, as we have seen, has found as a fact, that the covenant to commence and prosecute with due diligence— unavoidable accidents excepted—the sinking.and boring of one well on or in the vicinity of this lease to a depth of 1,200 feet, unless oil in paying quantities is sooner found, within six months from the date of the lease, has been fully performed by the plaintiffs; but he takes the position in his opinion that the instrument as a whole is simply an oil lease, and that the phrase, “prosecute the same,” appearing in the first covenant quoted, required' the plaintiffs to continue the boring of oil wells upon the premises until oil was obtained in paying quantities, and that by failing to do this they forfeited their rights under the lease. The difficulty with the learned referee’s conclusion is, that the lease is for “all oil or gases found,” and that no such covenant appears in the lease. . Had the lease contained such a covenant, we should not hesitate to agree with him that there was a forfeiture. The covenant is not that they shall commence operations within two years and prosecute the same with diligence until oil in paying quantities is found or forfeit their rights, under the lease, but it is, thqt they shall commence operations and prosecute the same within two years from the date of the lease, or thereafter pay to the party of the first part dollars per until the work is commenced. Quite a different covenant;, and the referee has failed to point out any particular in which this covenant has been violated. But again, it will be observed that in this covenant blanks appear constituting a patent ambiguity, which cannot even be supplied by paroi evidence, the blanks appear in the vital and essential part of the covenant; they affect the entire covenant, and it consequently is void for uncertainty. 2 Parsons on Contracts, 557, 563; The Blossburg and Corning Railroad Company v. The Tioga Railroad Company, 1 Keyes, 486; Vandevoort v. Dewey, manuscript opinion, Haight, J., general term, fifth department, June, 1886. The cases relied upon by the respondents are clearly distinguishable.

In the case of the Allegany Oil Company, Limited v. The Bradford Oil Company, (21 Hun. 26), the lease provided that unless the lessee should commence to bore the well within the period of nine months from the date thereof that then the lease was to become void and cease to be of any binding effect. The lessee did not commence operations at all within the period agreed upon. The lease was therefore forfeited by its express provisions.

In the case of Brown v. Vandergrift, (80 Pa. St., 142) the lease provided that the lessee should commence operations in sixty days and continue with due diligence and if he should cease operations twenty days at any one time the lessor might resume possession, and that in case the lessee did not commence operations within the time specified he should pay thirty dollars per month until he should commence. He did not commence operations within the time and paid four months’rent, but omitted to pay for the next eleven months. After the premises had been again leased and the lessee thereunder had entered into the' possession thereof the first lessee tendered the eleven months rent past due. It was held that the lease was forfeited.

In the case of Munroe v. Armstrong (96 Pa. St.,) the lease was made exclusively for the purpose of producing oil. It provided that the work of boring for oil was to be commenced in ten days and continued with due diligence until success or abandonment, and if the lessee failed to get oil in paying quantities or ceased work for thirty days at any time the lease was to be forfeited and be void. It was held that a cessation of work for thirty days forfeited the lease in accordance with its express provisions.

The particulars in which the contracts in these cases differ from the one under consideration will readily be observed for it contained no such forfeiture clause as appears in those cases.

The referee also appeared to be of the impression that this lease was hard and unconscionable and that equity would not enforce the performance of it for the reason that it contained no provision for giving the lessor any part of the gas found upon the premises, that the plaintiffs might proceed and cover the premises with gas wells and the lessor could obtain no benefit therefrom. The courts, however, are not called upon to make contracts for parties. If it was the understanding of the parties that the lessor should have one-eighth of the gas as well as of the oil found, and that clause was omitted from the contract through mistake it may still be reformed so as to express the intention of the parties. If, however, it was the intention of the parties that the lessor should have one-eighth, of the oil only and that the lessee should have all of the gas found in consideration for their testing the territory for oil then we see no reason why the parties should not abide by the contract as made. True, the lessor would derive no income from the that found the would have no right to deprive the plaintiffs of their right to the same.

If the theory of the referee is correct, it would be the duty of the plaintiffs to continue to bore wells upon these premises until oil was found in paying quantities, and then if not found in paying quantities, and they ceased to bore further wells, even though a well had been bored upon each acre of the land, still they would forfeit their rights under their lease, even though every well was a valuable gas well. The plaintiffs, as the referee has found, have already expended §3,000 in boring the first well. It is quite possible that this sum is largely in" excess of the value of the entire fifteen acres for farming purposes. It is quite as hard and unconscionable to now deprive them of the right to use this valuable gas found by them and thus lose the money expended in the operation, as it would be to require the lessor to five up to the contract made by him.

Again, suppose oil had been discovered, but not in paying quantities, wells that would produce five or six barrels of oil per day, but not in sufficient quantities to pay the expenses of putting down the wells and gathering the same, could it be held that the plaintiffs forfeited their rights under the lease because it was not found in paying quantities? It appears to us that the contract should not be so construed. The plaintiffs having performed the covenants ■on their part would have the right to retain possession for the purpose of gathering the oil which they had discovered to reimburse themselves, as far as possible.

The respondents contend that the lease has expired by its ■own terms; that the provision providing that “the lessees to have and to hold the same for the term of twelve years from this date, or as long as oil is found in paying ■quantities,” fixed the term only for that period during which oil was found in paying quantities. If so, it must have expired before the plaintiffs commenced operations, for no oil was found in paying quantities after the date of the lease and before the well was bored. Such could not have been the meaning or intention of the parties. The term was for twelve years, or as long as oil is found in paying quantities, meaning twelve years, and as much longer as oil is found in paying quantities.

The judgment should be reversed and a new trial ordered before another referee, with costs to abide the event.

Smith, P. J., Barker and Bradley, JJ., concur.