Task: sc_issue_9

What follows is an opinion from the Supreme Court of the United States. Your task is to determine the issue of the Court's decision. Determine the issue of the case on the basis of the Court's own statements as to what the case is about. Focus on the subject matter of the controversy rather than its legal basis.

Me. Justice Douglas delivered the opinion of the Court.
The question presented in this case is whether the Department of Justice may challenge the finality of a contract disputes decision made by the Atomic Energy Commission (AEC) in favor of its contractor, where the contract provides that the decision of AEC shall be “final and conclusive.” Section 1 of the Wunderlich Act leaves open for contest a claim that “is fraudulent or capricious or arbitrary or so grossly erroneous as necessarily to imply bad faith, or is not supported by substantial evidence.”
Moreover, 41 U. S. C. § 322, provides that “[n]o government contract shall contain a provision making final on a question of law the decision of any administrative official, representative, or board.”
The Department of Justice challenged the settlement made by the AEC on two grounds, (1) that the decision was “not supported by substantial evidence” and (2) that it was “erroneous as a matter of law.”
But the disputes clause in the contract says that the decision of the AEC is “final and conclusive,” unless a court determines that the award is vulnerable under §§ 1 and 2 of the Act. There is no federal statute which submits disputes of this character to review by one or more administrative agencies, where as here there is no charge of fraud or bad faith. Nor is there a statute which enables another federal agency to contest in court the validity of the decision of the AEC, absent fraud or bad faith.
In plain lay language the question then is whether, absent fraud or bad faith, the contractor can rely on the ruling of the federal agency with which it made the contract or can be forced to go through still another tier of federal review. We hold that absent fraud or bad faith the federal agency’s settlement under the disputes clause is binding on the Government; that there is not another tier of administrative review; and that, save for fraud or bad faith, the decision of AEC is “final and conclusive,” it being for these purposes the Federal Government. We reverse the judgment of the Court of Claims.
I
On August 4, 1961, petitioner contracted with the AEC to build a testing facility at the National Reactor Test Station in Idaho. The work was completed and accepted by the AEC on June 29, 1962. Because of various changes in contract specifications and difficulties in meeting performance schedules, petitioner submitted a series of claims to the contracting officer for resolution under the standard disputes clause contained in the contract, asking for equitable modifications of the contract and additional compensation. On August 8 and November 8, 1962, the contracting officer approved some of the claims and disapproved others, and the petitioner sought review of the adverse decisions with the AEC.
Since it did not then have a contract appeals board, the Commission referred petitioner’s appeal to a hearing examiner, before whom an adversary hearing was held. On June 26, 1963, the examiner decided in favor of eight of petitioner’s claims and remanded the dispute to the contracting officer for negotiations to determine the exact amount due petitioner. 2 A. E. C. 631. The contracting officer then sought review of this decision by the Commission. See 10 CER § 2.760 (Jan. 1, 1963).
The Commission declined to review four of the claims, 2 A. E. C. 738, which had the effect of sustaining the examiner’s decision on them. 10 CFR § 2.762 (a) (Jan. 1, 1963). Included within this group was the examiner’s determination that amounts due petitioner could not be retained to offset claims allegedly owed by petitioner to other contractors and other agencies of government. The Commission modified the examiner’s decision on three of the remaining claims and reversed him on the last, which petitioner has since abandoned. It “remanded to the contracting officer with instructions to proceed to final settlement or decision in accordance with the decision of the hearing examiner dated June 26, 1963, as modified by [its] order of November 14, 1963, and by [that] decision.” 2 A. E. C. 860, 856.
On March 6, 1964, prior to the AEC’s final ruling but after it had upheld the examiner’s decision on the “re-tainage” claim, a certifying officer of the Commission requested the opinion of the General Accounting Office on whether a voucher for the retainage claim could be certified for payment. Jurisdiction for the Comptroller General’s review was purportedly founded upon 31 U. S. C. § 82d. After some 33 months of what amounted to a plenary review of the proceedings before the examiner, the Comptroller General concluded that the voucher could not be certified for payment. 46 Comp. Gen. 441. On March 27, 1967, the AEC wrote petitioner, saying, “The Atomic Energy Commission’s view is that S&E Contractors, Inc. has exhausted its administrative recourse to the Commission. The Commission will take no action, in connection with the claims, inconsistent with the views expressed by the Comptroller General....” The petitioner then brought this action in the Court of Claims seeking a judgment of $1.95 million and an order remanding the case for negotiations on the time extension to which it claimed it was entitled under the AEC’s original decision.
The defenses tendered raised no issue of any fraud or bad faith of the contractor against the United States.
On cross-motions for summary judgment, a commissioner of the Court of Claims ruled in favor of petitioner, holding that the General Accounting Office lacked authority to review the decision of the AEC and that the AEC’s refusal to follow its own decisions favorable to petitioner was a breach of the disputes clause of the contract. On review by the Court of Claims, however, that decision was reversed by a four-to-three vote. While the majority acknowledged “that the Comptroller General effectively stopped payment of the claims,” it did not pass upon the legality of that action. 193 Ct. Cl. 335, 340, 433 P. 2d 1373, 1375. Reasoning, instead, that the Wunder-lich Act allowed both the Department of Justice and contractors an equal right to judicial review of administrative decisions and that the AEC’s refusal to abide by its earlier decision was a permissible means of obtaining this review, it remanded petitioner’s claims “to the commissioner for his consideration and report on the various claims under Wunderlich Act standards.” Id., at 351, 433 F. 2d, at 1381.
The Commissioner did not base his opinion on any issue of fraud or bad faith of the contractor against the United States, nor did the Court of Claims. The case is now here on a petition for writ of certiorari which we granted. 402 U. S. 971.
Petitioner argues that neither the text nor the legislative history of the Wunderlich Act supports the right of the United States to seek judicial review of an administrative decision on a contractual dispute, that the General Accounting Office was without statutory or contractual authority to overturn the AEC’s decision, and that the AEC should not be allowed to abandon after some 33 months its own decision that had been made in petitioner’s favor. In response, the Solicitor General contends that the Wunderlich Act does give the Department of Justice the right of judicial review of contract decisions made by federal administrative agencies and that the Department of Justice is free to assert whatever defenses it desires in the Court of Claims without regard to the earlier actions of the federal contracting agency.
II
The disputes clause included in Government contracts is intended, absent fraud or bad faith, to provide a quick and efficient administrative remedy and to avoid “vexatious and expensive and, to the contractor oftentimes, ruinous litigation.” Kihlberg v. United States, 97 U. S. 398, 401 (1878). The contractor has ceded his right to seek immediate judicial redress for his grievances and has contractually bound himself to “proceed diligently with the performance of the contract” during the disputes process. The purpose of avoiding “vexatious litigation” would not be served, however, by substituting the action of officials acting in derogation of the contract.
The result in some cases might be sheer disaster. In the present case nearly a decade has passed since petitioner completed the performance of a contract under which the only agency empowered to act determined that it was entitled to payment. To postpone payment for such a period is to sanction precisely the sort of “vexatious litigation” which the disputes process was designed to avoid.
5 The American Bar Association, as amicus curiae, notes “that the contractor’s consent to permit a specific representative of the Government to decide disputes — the Commission — should not be read as permitting any different representative of the Government to'veto’ decisions rendered by the Commission which are in favor of the contractor.”
Here, petitioner contracted with the United States acting through the AEC and it was exclusively with this Commission that the administrative resolution of disputes rested. Disputes initially were to be resolved between the contractor and the contracting officer and, if a settlement satisfactory to the contractor could be reached at that level, no review would lie. See United States v. Mason & Hanger Co., 260 U. S. 323; United States v. Corliss Steam-Engine Co., 91 U. S. 321.
By the disputes clause the decision of the AEC is “final and conclusive” unless “a court of competent jurisdiction” decides otherwise for the enumerated reasons. Neither the Wunderlich Act nor the disputes clause empowers any other administrative agency to have a veto of the AEC’s “final” decision or authority to review it. Nor does any other Act of Congress, except where fraud or bad faith is involved, give any other part of the Executive Branch authority to submit the matter to any court for determination. In other words, we cannot infer that by some legerdemain the disputes clause submitted the dispute to further administrative challenge or approval, and did not mean what it says when it made the AEC’s decision “final and conclusive.” See United States v. Mason & Hanger Co., supra, at 326. Kipps, The Right of the Government to Have Judicial Review of a Board of Contract Appeals Decision Made Under the Disputes Clause, 2 Pub. Contract L. J. 286 (1969); Schultz, Wunderlich Revisited: New Limits on Judicial Review of Administrative Determination of Government Contract Disputes, 29 Law & Contemp. Prob. 115, 132-133 (1964).
A citizen has the right to expect fair dealing from his government, see VitareUi v. Seaton, 359 U. S. 535, and this entails in the present context treating the government as a unit rather than as an amalgam of separate entities. Here, the AEC spoke for the United States and its decision, absent fraud or bad faith, should be honored. Cf. NLRB v. Nash-Finch Co., 404 U. S. 138.
Since the AEC withheld payment solely because of the views of the Comptroller General and since he had been given no authority to function as another tier of administrative review, there was no valid reason for the AEC not to settle with petitioner according to its earlier decision. For that purpose the AEC was the United States. Cf. Small Business Administration v. McClellan, 364 U. S. 446, 449.
The cases deny review by the Comptroller General of administrative disputes clause decisions as “without legal authority” absent fraud or overreaching. E. g., McShain Co. v. United States, 83 Ct. Ct. 405, 409 (1936). In James Graham Mfg. Co. v. United States, 91 F. Supp. 715 (ND Cal. 1950), for example, the contracting agency had determined that the contractor was entitled to reimbursement for certain expenditures under two cost-plus-fee contracts, but the Comptroller General refused payment. While the court noted the “extensive and broad” powers of the Comptroller General, it held that, absent instances of “fraud or overreaching,” where the Comptroller General’s power was founded upon specific statutory provisions such as 41 U. S. C. § 53, he had no “authority to determine the propriety of contract payments” approved by the contracting agency. 91 F. Supp., at 716. Accordingly, summary judgment was entered by the court, which said, “Since the Navy Department has determined that plaintiff contractor is entitled to the payment sought, this Court must adjudge accordingly.” Id., at 717.
Congress contemplated giving the General Accounting Office such powers and, indeed, the Senate twice passed— in the form of the McCarran bill — a provision which would have allowed the Comptroller to review disputes decisions to determine if they were “fraudulent, grossly erroneous, so mistaken as necessarily to imply bad faith, or not supported by reliable, probative, and substantial evidence.” S. 24, 83d Cong., 1st Sess. (1953). “If enacted, it would [have] invest [ed] the GAO with the power — which it has never had — to upset an administrative decision which it [found] 'grossly erroneous’ or 'not supported by reliable, probative, and substantial evidence.’ ” Schultz, Proposed Changes in Government Contract Disputes Settlement: The Legislative Battle over the Wunderlich Case, 67 Harv. L. Rev. 217, 243 (1953). The House of Representatives rejected this provision, however, and the Wunderlich Act was ultimately passed in its present form. We cannot, therefore, construe it to give the Comptroller General powers which Congress has plainly denied.
It is suggested, however, that the Comptroller General’s power is not one of review over the AEC decision but is merely the power “to force the contractor to bring suit and thus to obtain judicial review for the Government.” The disputes clause, however, sets forth the administrative means for resolving contractual disputes. Under the present contract the AEC is the final administrative arbiter of such claims and nowhere is there a provision for oversight by the Comptroller General. The Comptroller General, however, conducted a 33-month de novo review of the AEC proceedings; he blocked the payment to which the AEC determined petitioner was entitled; and he placed upon petitioner the burden of going to the Court of Claims to receive that payment. That action by the Comptroller General was a form of additional administrative oversight foreclosed by the disputes clause.
Ill
A majority of the Court of Claims held “that the Government has the right to the same extent as the contractor to seek judicial review of an unfavorable administrative decision on a contract claim.” 193 Ct. Cl., at 346, 433 F. 2d, at 1378. The Solicitor General adopts this view and sees in the Attorney General’s obligation to conduct litigation on behalf of the United States, 28 U. S. C. §§ 516, 519, the power to overturn decisions of coordinate offices of the Executive Department.
The Attorney General has the duty to “conduct... litigation in which the United States, an.agency, or officer thereof is a party,” 28 U. S. C. § 516, and to “supervise all [such] litigation,” 28 U. S. C. § 519. That power is pervasive but it does not appear how under the Wunderlich Act it gives the Department of Justice the right to appeal from a decision of the Atomic Energy Commission. Normally, where the responsibility for rendering a decision is vested in a coordinate branch of Government, the duty of the Department of Justice is to implement that decision and not to repudiate it. See 39 Op. Atty. Gen. 67, 68 (1937); 38 Op. Atty. Gen. 149, 150 (1934); 25 Op. Atty. Gen. 524, 529 (1905); 25 Op. Atty. Gen. 93, 96 (1903); 20 Op. Atty. Gen. 711, 713 (1894); 20 Op. Atty. Gen. 270, 272 (1891); 17 Op. Atty. Gen. 332, 333 (1882). Indeed, this view of the role of the Department of Justice may be traced back to William Wirt, the first of our Attorneys General to keep detailed records of his tenure in office. “Wirt it was who first recorded the propositions that the Attorney General does not decide questions of fact, that the Attorney General does not sit as an arbitrator in disputes between the government departments and private individuals nor as a reviewing officer to hear appeals from the decisions of public officers... H. Cummings & C. McFarland, Federal Justice 84 (1937) (footnotes omitted).
The power to appeal to the Court of Claims a decision of the federal agency under a disputes clause in a contract which the agency is authorized to make is not to be found in the Wunderlich Act and its underlying legislative history. That Act was designed to overturn our decision in United States v. Wunderlich, 342 U. S. 98 (1951), which had closed the courthouse doors to certain citizens aggrieved by administrative action amounting to something less than fraud. See S. Rep. No. 32, 83d Cong., 1st Sess.; H. R. Rep. No. 1380, 83d Cong., 2d Sess. It should not be construed to require a citizen to perform the Herculean task of beheading the Hydra in order to obtain justice from his Government.
We are reluctant to construe a statute enacted to free citizens from a form of administrative tyranny so as to subject them to additional bureaucratic oversight, where there is no evidence of fraud or overreaching. In-this connection, it should be noted that committee reports accompanying the Wunderlich Act indicate that judicial review was provided so that contractors would not inflate their bids to take into account the uncertainties of administrative action. This objective would be ill served if Government contractors — having won a favorable decision before the agencies with whom they contracted— had also to run the gantlet of the General Accounting Office and the Department of Justice.
IV
A contractor’s fraud is of course a wholly different genus than the case now before us. Even where the contractor has obtained a judgment and the time for review of it has expired, fraud on an administrative agency or on the court enforcing the agency action is ground for setting aside the judgment. “[S"Jetting aside the judgment to permit a new trial, altering the terms of the judgment, or restraining the beneficiaries of the judgment from taking any benefit whatever from it,” Hazel-Atlas Co. v. Hartford Co., 322 U. S. 238, 245, are the usual forms of relief which have been granted. Patents obtained with unclean hands and contracts that are based on those patents are similarly tainted and will not be enforced. Precision Co. v. Automotive Co., 324 U. S. 806. Contracts with the United States — like patents — are matters concerning far more than the interest of the adverse parties; they entail the public interest:
“[WJhere a suit in equity concerns the public interest as well as the private interests of the litigants this doctrine assumes even wider and more significant proportions. For if an equity court properly uses the maxim to withhold its assistance in such a case it not only prevents a wrongdoer from enjoying the fruits of his transgression but averts an injury to the public.” Id., at 815.
Congress has made elaborate provisions for dealing with fraudulent claims of contractors. Where the Comptroller General is convinced “that any settlement was induced by fraud,” he is directed to “certify... all the facts... to the Department of Justice, to the Administrator of General Services, and to the contracting agency concerned.” 58 Stat. 664, as amended, 41 U. S. C. §116 (b). The Administrator of General Services is also given broad powers of investigation and he is directed to give the Department of Justice “any information received by him indicating any fraudulent practices, for appropriate action.” 41 U. S. C. § 118 (d). Moreover, whenever “any contracting agency or the Administrator of General Services believes that any settlement was induced by

Question: What is the issue of the decision?
年. involuntary confession
数. habeas corpus
日. plea bargaining: the constitutionality of and/or the circumstances of its exercise
的. retroactivity (of newly announced or newly enacted constitutional or statutory rights)
月. search and seizure (other than as pertains to vehicles or Crime Control Act)
用. search and seizure, vehicles
成. search and seizure, Crime Control Act
名. contempt of court or congress
时. self-incrimination (other than as pertains to Miranda or immunity from prosecution)
件. Miranda warnings
一. self-incrimination, immunity from prosecution
请. right to counsel (cf. indigents appointment of counsel or inadequate representation)
中. cruel and unusual punishment, death penalty (cf. extra legal jury influence, death penalty)
据. cruel and unusual punishment, non-death penalty (cf. liability, civil rights acts)
码. line-up
不. discovery and inspection (in the context of criminal litigation only, otherwise Freedom of Information Act and related federal or state statutes or regulations)
新. double jeopardy
文. ex post facto (state)
下. extra-legal jury influences: miscellaneous
分. extra-legal jury influences: prejudicial statements or evidence
入. extra-legal jury influences: contact with jurors outside courtroom
人. extra-legal jury influences: jury instructions (not necessarily in criminal cases)
功. extra-legal jury influences: voir dire (not necessarily a criminal case)
上. extra-legal jury influences: prison garb or appearance
户. extra-legal jury influences: jurors and death penalty (cf. cruel and unusual punishment)
为. extra-legal jury influences: pretrial publicity
间. confrontation (right to confront accuser, call and cross-examine witnesses)
号. subconstitutional fair procedure: confession of error
取. subconstitutional fair procedure: conspiracy (cf. Federal Rules of Criminal Procedure: conspiracy)
回. subconstitutional fair procedure: entrapment
在. subconstitutional fair procedure: exhaustion of remedies
页. subconstitutional fair procedure: fugitive from justice
字. subconstitutional fair procedure: presentation, admissibility, or sufficiency of evidence (not necessarily a criminal case)
有. subconstitutional fair procedure: stay of execution
个. subconstitutional fair procedure: timeliness
作. subconstitutional fair procedure: miscellaneous
示. Federal Rules of Criminal Procedure
出. statutory construction of criminal laws: assault
是. statutory construction of criminal laws: bank robbery
失. statutory construction of criminal laws: conspiracy (cf. subconstitutional fair procedure: conspiracy)
表. statutory construction of criminal laws: escape from custody
除. statutory construction of criminal laws: false statements (cf. statutory construction of criminal laws: perjury)
加. statutory construction of criminal laws: financial (other than in fraud or internal revenue)
败. statutory construction of criminal laws: firearms
生. statutory construction of criminal laws: fraud
信. statutory construction of criminal laws: gambling
类. statutory construction of criminal laws: Hobbs Act; i.e., 18 USC 1951
置. statutory construction of criminal laws: immigration (cf. immigration and naturalization)
理. statutory construction of criminal laws: internal revenue (cf. Federal Taxation)
本. statutory construction of criminal laws: Mann Act and related statutes
息. statutory construction of criminal laws: narcotics includes regulation and prohibition of alcohol
行. statutory construction of criminal laws: obstruction of justice
定. statutory construction of criminal laws: perjury (other than as pertains to statutory construction of criminal laws: false statements)
改. statutory construction of criminal laws: Travel Act, 18 USC 1952
市. statutory construction of criminal laws: war crimes
期. statutory construction of criminal laws: sentencing guidelines
以. statutory construction of criminal laws: miscellaneous
修. jury trial (right to, as distinct from extra-legal jury influences)
元. speedy trial
方. miscellaneous criminal procedure (cf. due process, prisoners' rights, comity: criminal procedure)
录. voting
区. Voting Rights Act of 1965, plus amendments
单. ballot access (of candidates and political parties)
位. desegregation (other than as pertains to school desegregation, employment discrimination, and affirmative action)
型. desegregation, schools
法. employment discrimination: on basis of race, age, religion, illegitimacy, national origin, or working conditions.
县. affirmative action
存. slavery or indenture
品. sit-in demonstrations (protests against racial discrimination in places of public accommodation)
前. reapportionment: other than plans governed by the Voting Rights Act
称. debtors' rights
注. deportation (cf. immigration and naturalization)
值. employability of aliens (cf. immigration and naturalization)
输. sex discrimination (excluding sex discrimination in employment)
建. sex discrimination in employment (cf. sex discrimination)
能. Indians (other than pertains to state jurisdiction over)
大. Indians, state jurisdiction over
例. juveniles (cf. rights of illegitimates)
度. poverty law, constitutional
始. poverty law, statutory: welfare benefits, typically under some Social Security Act provision.
到. illegitimates, rights of (cf. juveniles): typically inheritance and survivor's benefits, and paternity suits
面. handicapped, rights of: under Rehabilitation, Americans with Disabilities Act, and related statutes
载. residency requirements: durational, plus discrimination against nonresidents
点. military: draftee, or person subject to induction
密. military: active duty
动. military: veteran
果. immigration and naturalization: permanent residence
图. immigration and naturalization: citizenship
提. immigration and naturalization: loss of citizenship, denaturalization
发. immigration and naturalization: access to public education
式. immigration and naturalization: welfare benefits
国. immigration and naturalization: miscellaneous
登. indigents: appointment of counsel (cf. right to counsel)
错. indigents: inadequate representation by counsel (cf. right to counsel)
者. indigents: payment of fine
认. indigents: costs or filing fees
误. indigents: U.S. Supreme Court docketing fee
接. indigents: transcript
关. indigents: assistance of psychiatrist
重. indigents: miscellaneous
第. liability, civil rights acts (cf. liability, governmental and liability, nongovernmental; cruel and unusual punishment, non-death penalty)
地. miscellaneous civil rights (cf. comity: civil rights)
如. First Amendment, miscellaneous (cf. comity: First Amendment)
设. commercial speech, excluding attorneys
目. libel, defamation: defamation of public officials and public and private persons
开. libel, privacy: true and false light invasions of privacy
事. legislative investigations: concerning internal security only
可. federal or state internal security legislation: Smith, Internal Security, and related federal statutes
要. loyalty oath or non-Communist affidavit (other than bar applicants, government employees, political party, or teacher)
代. loyalty oath: bar applicants (cf. admission to bar, state or federal or U.S. Supreme Court)
小. loyalty oath: government employees
选. loyalty oath: political party
标. loyalty oath: teachers
明. security risks: denial of benefits or dismissal of employees for reasons other than failure to meet loyalty oath requirements
编. conscientious objectors (cf. military draftee or military active duty) to military service
求. campaign spending (cf. governmental corruption):
列. protest demonstrations (other than as pertains to sit-in demonstrations): demonstrations and other forms of protest based on First Amendment guarantees
网. free exercise of religion
万. establishment of religion (other than as pertains to parochiaid:)
最. parochiaid: government aid to religious schools, or religious requirements in public schools
器. obscenity, state (cf. comity: privacy): including the regulation of sexually explicit material under the 21st Amendment
所. obscenity, federal
内. due process: miscellaneous (cf. loyalty oath), the residual code
体. due process: hearing or notice (other than as pertains to government employees or prisoners' rights)
通. due process: hearing, government employees
务. due process: prisoners' rights and defendants' rights
此. due process: impartial decision maker
商. due process: jurisdiction (jurisdiction over non-resident litigants)
序. due process: takings clause, or other non-constitutional governmental taking of property
化. privacy (cf. libel, comity: privacy)
消. abortion: including contraceptives
否. right to die
保. Freedom of Information Act and related federal or state statutes or regulations
使. attorneys' and governmental employees' or officials' fees or compensation or licenses
次. commercial speech, attorneys (cf. commercial speech)
机. admission to a state or federal bar, disbarment, and attorney discipline (cf. loyalty oath: bar applicants)
对. admission to, or disbarment from, Bar of the U.S. Supreme Court
量. arbitration (in the context of labor-management or employer-employee relations) (cf. arbitration)
查. union antitrust: legality of anticompetitive union activity
部. union or closed shop: includes agency shop litigation
性. Fair Labor Standards Act
和. Occupational Safety and Health Act
更. union-union member dispute (except as pertains to union or closed shop)
后. labor-management disputes: bargaining
证. labor-management disputes: employee discharge
题. labor-management disputes: distribution of union literature
确. labor-management disputes: representative election
格. labor-management disputes: antistrike injunction
了. labor-management disputes: jurisdictional dispute
于. labor-management disputes: right to organize
金. labor-management disputes: picketing
公. labor-management disputes: secondary activity
午. labor-management disputes: no-strike clause
円. labor-management disputes: union representatives
片. labor-management disputes: union trust funds (cf. ERISA)
空. labor-management disputes: working conditions
态. labor-management disputes: miscellaneous dispute
管. miscellaneous union
主. antitrust (except in the context of mergers and union antitrust)
天. mergers
自. bankruptcy (except in the context of priority of federal fiscal claims)
我. sufficiency of evidence: typically in the context of a jury's determination of compensation for injury or death
全. election of remedies: legal remedies available to injured persons or things
今. liability, governmental: tort or contract actions by or against government or governmental officials other than defense of criminal actions brought under a civil rights action.
来. liability, other than as in sufficiency of evidence, election of remedies, punitive damages
正. liability, punitive damages
说. Employee Retirement Income Security Act (cf. union trust funds)
意. state or local government tax
送. state and territorial land claims
容. state or local government regulation, especially of business (cf. federal pre-emption of state court jurisdiction, federal pre-emption of state legislation or regulation)
已. federal or state regulation of securities
结. natural resources - environmental protection (cf. national supremacy: natural resources, national supremacy: pollution)
会. corruption, governmental or governmental regulation of other than as in campaign spending
段. zoning: constitutionality of such ordinances, or restrictions on owners' or lessors' use of real property
计. arbitration (other than as pertains to labor-management or employer-employee relations (cf. union arbitration)
源. federal or state consumer protection: typically under the Truth in Lending; Food, Drug and Cosmetic; and Consumer Protection Credit Acts
色. patents and copyrights: patent
時. patents and copyrights: copyright
交. patents and copyrights: trademark
系. patents and copyrights: patentability of computer processes
过. federal or state regulation of transportation regulation: railroad
电. federal and some few state regulations of transportation regulation: boat
询. federal and some few state regulation of transportation regulation:truck, or motor carrier
符. federal and some few state regulation of transportation regulation: pipeline (cf. federal public utilities regulation: gas pipeline)
未. federal and some few state regulation of transportation regulation: airline
程. federal and some few state regulation of public utilities regulation: electric power
常. federal and some few state regulation of public utilities regulation: nuclear power
条. federal and some few state regulation of public utilities regulation: oil producer
当. federal and some few state regulation of public utilities regulation: gas producer
情. federal and some few state regulation of public utilities regulation: gas pipeline (cf. federal transportation regulation: pipeline)
口. federal and some few state regulation of public utilities regulation: radio and television (cf. cable television)
合. federal and some few state regulation of public utilities regulation: cable television (cf. radio and television)
车. federal and some few state regulations of public utilities regulation: telephone or telegraph company
实. miscellaneous economic regulation
组. comity: civil rights
版. comity: criminal procedure
周. comity: First Amendment
址. comity: habeas corpus
记. comity: military
二. comity: obscenity
同. comity: privacy
业. comity: miscellaneous
权. comity primarily removal cases, civil procedure (cf. comity, criminal and First Amendment); deference to foreign judicial tribunals
其. assessment of costs or damages: as part of a court order
进. Federal Rules of Civil Procedure including Supreme Court Rules, application of the Federal Rules of Evidence, Federal Rules of Appellate Procedure in civil litigation, Circuit Court Rules, and state rules and admiralty rules
试. judicial review of administrative agency's or administrative official's actions and procedures
验. mootness (cf. standing to sue: live dispute)
料. venue
传. no merits: writ improvidently granted
述. no merits: dismissed or affirmed for want of a substantial or properly presented federal question, or a nonsuit
集. no merits: dismissed or affirmed for want of jurisdiction (cf. judicial administration: Supreme Court jurisdiction or authority on appeal from federal district courts or courts of appeals)
多. no merits: adequate non-federal grounds for decision
无. no merits: remand to determine basis of state or federal court decision (cf. judicial administration: state law)
员. no merits: miscellaneous
报. standing to sue: adversary parties
他. standing to sue: direct injury
無. standing to sue: legal injury
服. standing to sue: personal injury
线. standing to sue: justiciable question
这. standing to sue: live dispute
制. standing to sue: parens patriae standing
将. standing to sue: statutory standing
处. standing to sue: private or implied cause of action
高. standing to sue: taxpayer's suit
子. standing to sue: miscellaneous
道. judicial administration: jurisdiction or authority of federal district courts or territorial courts
章. judicial administration: jurisdiction or authority of federal courts of appeals
手. judicial administration: Supreme Court jurisdiction or authority on appeal or writ of error, from federal district courts or courts of appeals (cf. 753)
库. judicial administration: Supreme Court jurisdiction or authority on appeal or writ of error, from highest state court
三. judicial administration: jurisdiction or authority of the Court of Claims
从. judicial administration: Supreme Court's original jurisdiction
支. judicial administration: review of non-final order
家. judicial administration: change in state law (cf. no merits: remand to determine basis of state court decision)
长. judicial administration: federal question (cf. no merits: dismissed for want of a substantial or properly presented federal question)
付. judicial administration: ancillary or pendent jurisdiction
秒. judicial administration: extraordinary relief (e.g., mandamus, injunction)
路. judicial administration: certification (cf. objection to reason for denial of certiorari or appeal)
完. judicial administration: resolution of circuit conflict, or conflict between or among other courts
象. judicial administration: objection to reason for denial of certiorari or appeal
则. judicial administration: collateral estoppel or res judicata
现. judicial administration: interpleader
京. judicial administration: untimely filing
转. judicial administration: Act of State doctrine
辑. judicial administration: miscellaneous
限. Supreme Court's certiorari, writ of error, or appeals jurisdiction
力. miscellaneous judicial power, especially diversity jurisdiction
学. federal-state ownership dispute (cf. Submerged Lands Act)
外. federal pre-emption of state court jurisdiction
调. federal pre-emption of state legislation or regulation. cf. state regulation of business. rarely involves union activity. Does not involve constitutional interpretation unless the Court says it does.
项. Submerged Lands Act (cf. federal-state ownership dispute)
北. national supremacy: commodities
工. national supremacy: intergovernmental tax immunity
笑. national supremacy: marital and family relationships and property, including obligation of child support
监. national supremacy: natural resources (cf. natural resources - environmental protection)
任. national supremacy: pollution, air or water (cf. natural resources - environmental protection)
相. national supremacy: public utilities (cf. federal public utilities regulation)
微. national supremacy: state tax (cf. state tax)
册. national supremacy: miscellaneous
联. miscellaneous federalism
平. boundary dispute between states
增. non-real property dispute between states
听. miscellaneous interstate relations conflict
解. incorporation of foreign territories
等. federal taxation, typically under provisions of the Internal Revenue Code
得. federal taxation of gifts, personal, business, or professional expenses
收. priority of federal fiscal claims: over those of the states or private entities
安. miscellaneous federal taxation (cf. national supremacy: state tax)
价. legislative veto
藏. executive authority vis-a-vis congress or the states
命. miscellaneous
应. real property
看. personal property
索. contracts
资. evidence
产. civil procedure
串. torts
布. wills and trusts
原. commercial transactions
Answer:

Answer: 试