Source: https://regulations.justia.com/regulations/fedreg/2015/12/18/2015-31848.html
Timestamp: 2020-06-01 02:59:22
Document Index: 100364968

Matched Legal Cases: ['art 242', 'art 242', 'art 242', 'art 242', 'art 242', 'art 242', 'art 242', 'art 252', 'art 232', 'art 242', 'art 242', 'art 242', 'art 242', 'art 252']

Information Collection Requirements; Defense Federal Acquisition Regulation Supplement; DFARS Part 242, Contract Administration and Related Clause in DFARS 252, 79033-79034 [2015-31848] :: Defense Acquisition Regulations System :: Department Of Defense :: Regulation Tracker :: Justia
Justia Regulation Tracker Department Of Defense Defense Acquisition Regulations System Information Collection Requirements; Defense Federal Acquisition Regulation Supplement; DFARS Part 242, Contract Administration and Related Clause in DFARS 252, 79033-79034 [2015-31848]
Information Collection Requirements; Defense Federal Acquisition Regulation Supplement; DFARS Part 242, Contract Administration and Related Clause in DFARS 252, 79033-79034 [2015-31848]
Download as PDF Federal Register / Vol. 80, No. 243 / Friday, December 18, 2015 / Notices Average minutes per response: 10 minutes. Burden hours: 1,668 hours. An agency may not conduct or sponsor, and a person is not required to respond to, a collection of information unless it displays a currently valid Office of Management and Budget control number. OMB Desk Officer: Ms. Jasmeet Seehra. Comments and recommendations on the proposed information collection should be emailed to Ms. Jasmeet Seehra, DoD Desk Officer, at Oira_ submission@omb.eop.gov. Please identify the proposed information collection by DoD Desk Officer and the Docket ID number and title of the information collection. You may also submit comments and recommendations, identified by Docket ID number and title, by the following method: • Federal eRulemaking Portal: http:// www.regulations.gov. Follow the instructions for submitting comments. Instructions: All submissions received must include the agency name, Docket ID number and title for this Federal Register document. The general policy for comments and other submissions from members of the public is to make these submissions available for public viewing on the Internet at http:// www.regulations.gov as they are received without change, including any personal identifiers or contact information. DOD Clearance Officer: Mr. Frederick Licari. Written requests for copies of the information collection proposal should be sent to Mr. Licari at WHS/ESD Directives Division, 4800 Mark Center Drive, East Tower, Suite 02G09, Alexandria, VA 22350–3100. Dated: December 15, 2015. Aaron Siegel, Alternate OSD Federal Register Liaison Officer, Department of Defense. [FR Doc. 2015–31826 Filed 12–17–15; 8:45 am] mstockstill on DSK4VPTVN1PROD with NOTICES BILLING CODE 5001–06–P VerDate Sep<11>2014 19:20 Dec 17, 2015 Jkt 238001 DEPARTMENT OF DEFENSE Defense Acquisition Regulations System [Docket Number DARS–2015–0059] Information Collection Requirements; Defense Federal Acquisition Regulation Supplement; DFARS Part 242, Contract Administration and Related Clause in DFARS 252 Defense Acquisition Regulations System, Department of Defense (DoD). ACTION: Notice and request for comments regarding a proposed extension of an approved information collection requirement. AGENCY: In compliance with section 3506(c)(2)(A) of the Paperwork Reduction Act of 1995 (44 U.S.C. chapter 35), DoD announces the proposed extension of a public information collection requirement and seeks public comment on the provisions thereof. DoD invites comments on: (a) Whether the proposed collection of information is necessary for the proper performance of the functions of DoD, including whether the information will have practical utility; (b) the accuracy of the estimate of the burden of the proposed information collection; (c) ways to enhance the quality, utility, and clarity of the information to be collected; and (d) ways to minimize the burden of the information collection on respondents, including the use of automated collection techniques or other forms of information technology. The Office of Management and Budget (OMB) has approved this information collection requirement for use through April 30, 2016. DoD proposes that OMB extend its approval for three additional years. DATES: DoD will consider all comments received by February 16, 2016. ADDRESSES: You may submit comments, identified by OMB Control Number 0704–0250, using any of the following methods: Æ Federal eRulemaking Portal: http:// www.regulations.gov. Follow the instructions for submitting comments. Æ Email: osd.dfars@mail.mil. Include OMB Control Number 0704–0250 in the subject line of the message. Æ Fax: 571–372–6094. Æ Mail: Defense Acquisition Regulations System, Attn: Ms. Tresa Sullivan, OUSD(AT&L)DPAP(DARS), 3B941, 3060 Defense Pentagon, Washington, DC 20301–3060. Comments received generally will be posted without change to http:// SUMMARY: PO 00000 Frm 00006 Fmt 4703 Sfmt 4703 79033 www.regulations.gov, including any personal information provided. To confirm receipt of your comment(s), please check www.regulations.gov approximately two to three days after submission to verify posting, (except allow 30 days for posting of comments submitted by mail). FOR FURTHER INFORMATION CONTACT: Ms. Tresa Sullivan, 571–372–6089. SUPPLEMENTARY INFORMATION: Title and OMB Number: Information Collection in Support of the Defense Federal Acquisition Regulation Supplement (DFARS) Part 242; Contract Administration and related clause in DFARS 252; OMB Control Number 0704–0250. Needs and Uses: The Government requires this information in order to perform its contract administration functions. DoD uses the information as follows: a. The information required by DFARS subpart 242.11 is used by contract administration offices to monitor contract progress, identify factors that may delay contract performance, and to ascertain potential contract delinquencies. b. The information required by DFARS 252.242–7004 is used by contracting officers to determine if contractor material management and accounting systems conform to established DoD standards. Affected Public: Businesses or other for-profit, and not-for-profit institutions. Type of Request: Extension. Number of Respondents: 7,418. Responses per Respondent: 12.8. Annual Responses: 94,963. Average Burden per Response: 2.02 hours, approximately. Annual Burden Hours: 192,372. Reporting Frequency: On occasion. Summary of Information Collection This information collection includes requirements relating to DFARS part 242, Contract Administration and Audit Services, and the related clause at DFARS part 252. a. DFARS 242.11 requires DoD contract administration personnel to perform production surveillance to monitor contractor progress and identify any factors that may delay performance. The Government relies on the production progress reports provided by the contractor in the performance of this function. (2) DFARS 252.242–7004 requires a contractor to establish and maintain a material management and accounting system for applicable contracts, to provide results of system reviews, and E:\FR\FM\18DEN1.SGM 18DEN1 79034 Federal Register / Vol. 80, No. 243 / Friday, December 18, 2015 / Notices disclose significant changes in its system. Jennifer L. Hawes, Editor, Defense Acquisition Regulations System. [FR Doc. 2015–31848 Filed 12–17–15; 8:45 am] BILLING CODE 5001–06–P DEPARTMENT OF DEFENSE Defense Acquisition Regulations System [Docket Number DARS–2015–0058] Information Collection Requirement; Defense Federal Acquisition Regulation Supplement (DFARS); Contract Financing Defense Acquisition Regulations System, Department of Defense (DoD). ACTION: Notice. AGENCY: The Defense Acquisition Regulations System has submitted to OMB for clearance, the following proposal for collection of information under the provisions of the Paperwork Reduction Act (44 U.S.C. chapter 35). DATES: Consideration will be given to all comments received by January 19, 2016. SUPPLEMENTARY INFORMATION: Title, Associated Form, and OMB Number: Defense Federal Acquisition Regulation Supplement (DFARS) Part 232, Contract Financing, and the Clause at 252.232–7002, Progress Payments for Foreign Military Sales Acquisitions; OMB Control Number 0704–0321. Type of Request: Extension. Number of Respondents: 124. Responses per Respondent: Approximately 26.6. Annual Responses: 3,300. Average Burden per Response: 1.5 hours. Annual Burden Hours: 4,950 (includes 1,650 response hours plus 3,300 recordkeeping hours). Needs and Uses: Section 22 of the Arms Export Control Act (22 U.S.C. 2762) requires the U.S. Government to use foreign funds, rather than U.S. appropriated funds, to purchase military equipment for foreign governments. To comply with this requirement, the Government needs to know how much to charge each country. The clause at 252.232–7002, Progress Payments for Foreign Military Sales Acquisitions, requires each contractor whose contract includes foreign military sales (FMS) requirements to submit a separate progress payment request for each progress payment rate, and to submit a supporting schedule that clearly mstockstill on DSK4VPTVN1PROD with NOTICES SUMMARY: VerDate Sep<11>2014 19:20 Dec 17, 2015 Jkt 238001 distinguishes the contract’s FMS requirements from U.S. requirements. The Government uses this information to determine how much of each country’s funds to disburse to the contractor. Affected Public: Businesses or other for-profit and not-for-profit institutions. Frequency: On occasion. OMB Desk Officer: Ms. Jasmeet Seehra. Written comments and recommendations on the proposed information collection should be sent to Ms. Seehra at the Office of Management and Budget, Desk Officer for DoD, Room 10236, New Executive Office Building, Washington, DC 20503. You may also submit comments, identified by docket number and title, by the following method: Federal eRulemaking Portal: http:// www.regulations.gov. Follow the instructions for submitting comments. Instructions: All submissions received must include the agency name, docket number, and title for the Federal Register document. The general policy for comments and other public submissions from members of the public is to make these submissions available for public viewing on the internet at http://www.regulations.gov as they are received without change, including any personal identifiers or contact information provided. To confirm receipt of your comment(s), please check http://www.regulations.gov approximately two to three days after submission to verify posting (except allow 30 days for posting of comments submitted by mail). DoD Public Collections Clearance Officer: Mr. Frederick C. Licari. Written requests for copies of the information collection proposal should be sent to Mr. Licari at: Publication Collections Program, WHS/ESD Information Management Division, 4800 Mark Center Drive, 2nd Floor, East Tower, Suite 02G09, Alexandria, VA 22350–3100. Jennifer L. Hawes, Editor, Defense Acquisition Regulations System. [FR Doc. 2015–31846 Filed 12–17–15; 8:45 am] BILLING CODE 5001–06–P PO 00000 Frm 00007 Fmt 4703 Sfmt 4703 DEPARTMENT OF DEFENSE Department of the Army, Corps of Engineers Notice of Intent To Prepare a Joint Environmental Impact Statement/ Environmental Impact Report and Conduct Scoping Meeting for the Corte Madera Creek Flood Control Project General Reevaluation Report and Integrated EIS/EIR, County of Marin, CA Department of the Army, U.S. Army Corps of Engineers, DoD. ACTION: Notice of Intent. AGENCY: The purpose of this notice is to initiate the scoping process for the preparation of an Integrated General Reevaluation Report and Environmental Impact Statement/Environmental Impact Report (EIS/EIR) for channel modification opportunities to Unit 2, 3 and 4 of the Corte Madera Creek Flood Control Project in Marin County, CA. DATES: A public scoping meeting will be held on January 14, 2016 from 6:00 to 8:00 p.m. (PST). Submit comments concerning this notice on or before February 1, 2016. ADDRESSES: The scoping meeting location is: the Marin Arts and Garden Center, 30 Sir Francis Drake Boulevard, Ross, CA 94957–9601. Mail written comments concerning this notice to: U.S. Army Corps of Engineers, San Francisco District, Planning Branch, ATTN: Stephen M. Willis, 1455 Market Street, San Francisco, CA 94103–1398. Comment letters should include the commenter’s physical mailing address, the project title and the Corps file number in the subject line. FOR FURTHER INFORMATION CONTACT: Stephen M. Willis, U.S. Army Corps of Engineers, San Francisco District, Planning Branch, 1455 Market Street, San Francisco CA 94103–1398, (415) 503–6861, stephen.m.willis2@usace.army.mil. SUMMARY: In accordance with the National Environmental Policy Act (NEPA), the U.S. Army Corps of Engineers intends to prepare an Environmental Impact Statement (EIS). The Corps will address channel modification opportunities to Unit 4 of Corte Madera Creek, Marin County, CA, in accordance with the Flood Control Act of 1962, Public Law 87–4, 87th Congress, 2nd Session, approved October 23, 1962, and amended by Section 204 of Public Law 89–789, the Flood Control Act of 1966, and the Water Resources Development Act of 1986. Modifications to Unit 4 SUPPLEMENTARY INFORMATION: E:\FR\FM\18DEN1.SGM 18DEN1
[Federal Register Volume 80, Number 243 (Friday, December 18, 2015)]
[Pages 79033-79034]
[FR Doc No: 2015-31848]
[Docket Number DARS-2015-0059]
Information Collection Requirements; Defense Federal Acquisition
Regulation Supplement; DFARS Part 242, Contract Administration and
Related Clause in DFARS 252
requirement for use through April 30, 2016. DoD proposes that OMB
extend its approval for three additional years.
DATES: DoD will consider all comments received by February 16, 2016.
0704-0250, using any of the following methods:
0250 in the subject line of the message.
[cir] Mail: Defense Acquisition Regulations System, Attn: Ms. Tresa
Sullivan, OUSD(AT&L)DPAP(DARS), 3B941, 3060 Defense Pentagon,
FOR FURTHER INFORMATION CONTACT: Ms. Tresa Sullivan, 571-372-6089.
Title and OMB Number: Information Collection in Support of the
Defense Federal Acquisition Regulation Supplement (DFARS) Part 242;
Contract Administration and related clause in DFARS 252; OMB Control
Number 0704-0250.
Needs and Uses: The Government requires this information in order
to perform its contract administration functions. DoD uses the
a. The information required by DFARS subpart 242.11 is used by
contract administration offices to monitor contract progress, identify
factors that may delay contract performance, and to ascertain potential
contract delinquencies.
b. The information required by DFARS 252.242-7004 is used by
contracting officers to determine if contractor material management and
accounting systems conform to established DoD standards.
Affected Public: Businesses or other for-profit, and not-for-profit
Number of Respondents: 7,418.
Responses per Respondent: 12.8.
Annual Responses: 94,963.
Average Burden per Response: 2.02 hours, approximately.
Annual Burden Hours: 192,372.
This information collection includes requirements relating to DFARS
part 242, Contract Administration and Audit Services, and the related
clause at DFARS part 252.
a. DFARS 242.11 requires DoD contract administration personnel to
perform production surveillance to monitor contractor progress and
identify any factors that may delay performance. The Government relies
on the production progress reports provided by the contractor in the
performance of this function.
(2) DFARS 252.242-7004 requires a contractor to establish and
maintain a material management and accounting system for applicable
contracts, to provide results of system reviews, and
disclose significant changes in its system.
[FR Doc. 2015-31848 Filed 12-17-15; 8:45 am]