Source: https://law.lis.virginia.gov/vacodefull/title2.2/chapter43/
Timestamp: 2018-05-25 22:46:52
Document Index: 465781777

Matched Legal Cases: ['§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 38', '§ 11', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 15', '§ 2', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 11', '§ 11', '§ 2', '§ 2', '§ 11', '§ 2', '§ 58', '§ 58', '§ 58', '§ 2', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 11', '§ 11', '§ 11', '§ 11', '§ 2', '§ 2000', '§ 11', '§ 2', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 11', '§ 2', '§ 2', '§ 2', '§ 11', '§ 2', '§ 2', '§ 11', '§ 2', '§ 11']

Code of Virginia Code - Chapter 43. Virginia Public Procurement Act
Table of Contents » Title 2.2. Administration of Government » Chapter 43. Virginia Public Procurement Act
Chapter 43. Virginia Public Procurement Act.
§ 2.2-4300. Short title; purpose; declaration of intent.
A. This chapter may be cited as the Virginia Public Procurement Act.
C. To the end that public bodies in the Commonwealth obtain high quality goods and services at reasonable cost, that all procurement procedures be conducted in a fair and impartial manner with avoidance of any impropriety or appearance of impropriety, that all qualified vendors have access to public business and that no offeror be arbitrarily or capriciously excluded, it is the intent of the General Assembly that competition be sought to the maximum feasible degree, that procurement procedures involve openness and administrative efficiency, that individual public bodies enjoy broad flexibility in fashioning details of such competition, that the rules governing contract awards be made clear in advance of the competition, that specifications reflect the procurement needs of the purchasing body rather than being drawn to favor a particular vendor, and that the purchaser and vendor freely exchange information concerning what is sought to be procured and what is offered. Public bodies may consider best value concepts when procuring goods and nonprofessional services, but not construction or professional services. The criteria, factors, and basis for consideration of best value and the process for the consideration of best value shall be as stated in the procurement solicitation.
1982, c. 647, § 11-35; 1983, c. 593; 1984, c. 764; 1986, cc. 149, 212, 559; 1994, cc. 661, 918; 1995, c. 18; 1996, cc. 683, 1019; 1997, cc. 85, 488, 785, 861, 863; 1998, cc. 121, 132; 1999, cc. 230, 248, 735; 2000, cc. 29, 382, 400, 642, 644, 666, 703; 2001, cc. 392, 409, 736, 753, 774, 844.
§ 2.2-4302. Implementation.
This chapter may be implemented by ordinances, resolutions or regulations consistent with this chapter and with the provisions of other applicable law promulgated by any public body empowered by law to undertake the activities described in this chapter. Any such public body may act by and through its duly designated or authorized officers or employees.
1982, c. 647, § 11-36; 2001, c. 844.
1. Issuance of a written Request for Proposal indicating in general terms that which is sought to be procured, specifying the factors that will be used in evaluating the proposal, indicating whether a numerical scoring system will be used in evaluation of the proposal, and containing or incorporating by reference the other applicable contractual terms and conditions, including any unique capabilities, specifications or qualifications that will be required. In the event that a numerical scoring system will be used in the evaluation of proposals, the point values assigned to each of the evaluation criteria shall be included in the Request for Proposal or posted at the location designated for public posting of procurement notices prior to the due date and time for receiving proposals. No Request for Proposal for construction authorized by this chapter shall condition a successful offeror's eligibility on having a specified experience modification factor;
3. For goods, nonprofessional services, and insurance, selection shall be made of two or more offerors deemed to be fully qualified and best suited among those submitting proposals, on the basis of the factors involved in the Request for Proposal, including price if so stated in the Request for Proposal. In the case of a proposal for information technology, as defined in § 2.2-2006, a public body shall not require an offeror to state in a proposal any exception to any liability provisions contained in the Request for Proposal. Negotiations shall then be conducted with each of the offerors so selected. The offeror shall state any exception to any liability provisions contained in the Request for Proposal in writing at the beginning of negotiations, and such exceptions shall be considered during negotiation. Price shall be considered, but need not be the sole or primary determining factor. After negotiations have been conducted with each offeror so selected, the public body shall select the offeror which, in its opinion, has made the best proposal and provides the best value, and shall award the contract to that offeror. When the terms and conditions of multiple awards are so provided in the Request for Proposal, awards may be made to more than one offeror. Should the public body determine in writing and in its sole discretion that only one offeror is fully qualified, or that one offeror is clearly more highly qualified than the others under consideration, a contract may be negotiated and awarded to that offeror; or
4. For professional services, the public body shall engage in individual discussions with two or more offerors deemed fully qualified, responsible and suitable on the basis of initial responses and with emphasis on professional competence, to provide the required services. Repetitive informal interviews shall be permissible. The offerors shall be encouraged to elaborate on their qualifications and performance data or staff expertise pertinent to the proposed project, as well as alternative concepts. In addition, offerors shall be informed of any ranking criteria that will be used by the public body in addition to the review of the professional competence of the offeror. The Request for Proposal shall not, however, request that offerors furnish estimates of man-hours or cost for services. At the discussion stage, the public body may discuss nonbinding estimates of total project costs, including, but not limited to, life-cycle costing, and where appropriate, nonbinding estimates of price for services. In accordance with § 2.2-4342, proprietary information from competing offerors shall not be disclosed to the public or to competitors. For architectural or engineering services, the public body shall not request or require offerors to list any exceptions to proposed contractual terms and conditions, unless such terms and conditions are required by statute, regulation, ordinance, or standards developed pursuant to § 2.2-1132, until after the qualified offerors are ranked for negotiations. At the conclusion of discussion, outlined in this subdivision, on the basis of evaluation factors published in the Request for Proposal and all information developed in the selection process to this point, the public body shall select in the order of preference two or more offerors whose professional qualifications and proposed services are deemed most meritorious.
Negotiations shall then be conducted, beginning with the offeror ranked first. If a contract satisfactory and advantageous to the public body can be negotiated at a price considered fair and reasonable and pursuant to contractual terms and conditions acceptable to the public body, the award shall be made to that offeror. Otherwise, negotiations with the offeror ranked first shall be formally terminated and negotiations conducted with the offeror ranked second, and so on until such a contract can be negotiated at a fair and reasonable price.
B. Multiphase professional services contracts satisfactory and advantageous to the completion of large, phased, or long-term projects may be negotiated and awarded based on a fair and reasonable price for the first phase only, where the completion of the earlier phases is necessary to provide information critical to the negotiation of a fair and reasonable price for succeeding phases. Prior to entering into any such contract, the public body shall (i) state the anticipated intended total scope of the project and (ii) determine in writing that the nature of the work is such that the best interests of the public body require awarding the contract.
For the purposes of subdivision A 1, "experience modification factor" means a value assigned to an employer as determined by a rate service organization in accordance with its uniform experience rating plan required to be filed pursuant to subsection D of § 38.2-1913.
2013, cc. 518, 540, 543, 583; 2014, cc. 217, 630; 2015, cc. 350, 570, 760, 776; 2016, cc. 174, 175, 295, 362, 754.
Article 2. Contract Formation and Administration.
Such purchase procedures may allow for single or term contracts for professional services without requiring competitive negotiation, provided the aggregate or the sum of all phases is not expected to exceed $60,000.
1982, c. 647, § 11-41; 1985, c. 164; 1986, cc. 332, 559; 1987, c. 456; 1988, cc. 40, 640; 1989, c. 296; 1991, c. 73; 1993, c. 242; 1996, cc. 827, 965, 1019; 1999, c. 178; 2000, cc. 637, 647, 664, 692; 2001, cc. 395, 844; 2003, cc. 644, 895; 2004, cc. 706, 874, 906; 2005, c. 394; 2006, cc. 464, 510; 2008, c. 78; 2009, c. 123; 2010, c. 567; 2011, cc. 332, 594, 612, 681; 2012, cc. 805, 836; 2013, cc. 502, 583; 2015, cc. 760, 776; 2016, cc. 228, 604; 2017, cc. 699, 704.
B. In addition, a public body may purchase from another public body's contract or from the contract of the Metropolitan Washington Council of Governments or the Virginia Sheriffs' Association even if it did not participate in the request for proposal or invitation to bid, if the request for proposal or invitation to bid specified that the procurement was a cooperative procurement being conducted on behalf of other public bodies, except for:
2. Construction, except for the installation of artificial turf and track surfaces, including all associated and necessary construction, which shall not be subject to the limitations prescribed in this subdivision. Nothing in this subdivision shall be construed to prohibit sole source or emergency procurements awarded pursuant to subsections E and F of § 2.2-4303.
1982, c. 647, § 11-40; 1984, c. 330; 1987, c. 583; 1991, c. 645; 1996, cc. 261, 280, 1019; 2001, c. 844; 2003, cc. 651, 895, 981, 1021; 2004, cc. 874, 906, 911, 936; 2005, c. 394; 2006, c. 100; 2010, c. 736; 2015, cc. 352, 760, 776; 2016, c. 629; 2017, c. 636.
§ 2.2-4305. Competitive procurement by localities on state-aid projects.
No contract for the construction of any building or for an addition to or improvement of an existing building by any local governing body or subdivision thereof for which state funds of not more than $50,000 in the aggregate or for the sum of all phases of a contract or project either by appropriation, grant-in-aid or loan, are used or are to be used for all or part of the cost of construction shall be let except after competitive sealed bidding or after competitive negotiation as provided under subsection D of § 2.2-4303 or Chapter 43.1 (§ 2.2-4378 et seq.). The procedure for the advertising for bids or for proposals and for letting of the contract shall conform, mutatis mutandis, to this chapter.
1982, c. 647, § 11-41.1; 1983, c. 436; 1987, c. 456; 1989, c. 296; 1997, c. 163; 2001, c. 844; 2010, c. 382; 2017, cc. 699, 704.
§ 2.2-4308.1. Purchase of owner-controlled insurance in construction projects.
A. Notwithstanding any other provision of law to the contrary, a public body may purchase at its expense an owner-controlled insurance program in connection with any public construction contract where the amount of the contract or combination of contracts is more than $100 million, provided that no single contract valued at less than $50 million shall be combined pursuant to this section. The public body shall provide notice if it intends to use an owner-controlled insurance program, including the specific coverages of such program, in any request for proposal, invitation to bid, or other applicable procurement documents.
B. A public body shall not require a provider of architecture or professional engineering services to participate in the owner-controlled insurance program, except to the extent that the public body may elect to secure excess coverage. No contractor or subcontractor shall be required to provide insurance coverage for a construction project if that specified coverage is included in an owner-controlled insurance program in which the contractor or subcontractor is enrolled.
C. For the purposes of this section, "owner-controlled insurance program" means a consolidated insurance program or series of insurance policies issued to a public body that may provide for some or all of the following types of insurance coverage for any contractor or subcontractor working on or at a public construction contract or combination of such contracts: general liability, property damage, workers' compensation, employer's liability, pollution or environmental liability, excess or umbrella liability, builder's risk, and excess or contingent professional liability.
2006, cc. 569, 605.
B. Any public body may extend the term of an existing contract for services to allow completion of any work undertaken but not completed during the original term of the contract.
D. The provisions of this section shall not limit the amount a party to a public contract may claim or recover against a public body pursuant to § 2.2-4363 or any other applicable statute or regulation. Modifications made by a political subdivision that fail to comply with this section are voidable at the discretion of the governing body, and the unauthorized approval of a modification cannot be the basis of a contractual claim as set forth in § 2.2-4363.
1982, c. 647, §§ 11-45, 11-55; 1984, c. 764; 1985, c. 286; 1987, cc. 194, 248; 1989, c. 235; 1990, c. 395; 1991, c. 175; 1993, cc. 110, 505, 638, 971; 1996, cc. 145, 897, 902, 950, 1038; 1998, cc. 222, 619, 666, 697, 791; 1999, cc. 160, 194, 1021, 1024; 2000, cc. 242, 637, 664, 696, 927; 2001, c. 844; 2015, c. 569.
§ 2.2-4310. Discrimination prohibited; participation of small, women-owned, minority-owned, and service disabled veteran-owned business and employment services organization.
B. All public bodies shall establish programs consistent with this chapter to facilitate the participation of small businesses, businesses owned by women, minorities, and service disabled veterans, and employment services organizations in procurement transactions. The programs established shall be in writing and shall comply with the provisions of any enhancement or remedial measures authorized by the Governor pursuant to subsection C or, where applicable, by the chief executive of a local governing body pursuant to § 15.2-965.1, and shall include specific plans to achieve any goals established therein. State agencies shall submit annual progress reports on (i) small, women-owned, and minority-owned business procurement, (ii) service disabled veteran-owned business procurement, and (iii) employment services organization procurement to the Department of Small Business and Supplier Diversity in a form specified by the Department of Small Business and Supplier Diversity. Contracts and subcontracts awarded to employment services organizations shall be credited toward the small business, women-owned, and minority-owned business contracting and subcontracting goals of state agencies and contractors. The Department of Small Business and Supplier Diversity shall make information on service disabled veteran-owned procurement available to the Department of Veterans Services upon request.
C. Whenever there exists (i) a rational basis for small business or employment services organization enhancement or (ii) a persuasive analysis that documents a statistically significant disparity between the availability and utilization of women-owned and minority-owned businesses, the Governor is authorized and encouraged to require state agencies to implement appropriate enhancement or remedial measures consistent with prevailing law. Any enhancement or remedial measure authorized by the Governor pursuant to this subsection for state public bodies may allow for small businesses certified by the Department of Small Business and Supplier Diversity or a subcategory of small businesses established as a part of the enhancement program to have a price preference over noncertified businesses competing for the same contract award on designated procurements, provided that the bid of the certified small business or the business in such subcategory of small businesses established as a part of an enhancement program does not exceed the low bid by more than five percent.
D. In awarding a contract for services to a small, women-owned, or minority-owned business that is certified in accordance with § 2.2-1606, or to a business identified by a public body as a service disabled veteran-owned business where the award is being made pursuant to an enhancement or remedial program as provided in subsection C, the public body shall include in every such contract of more than $10,000 the following:
"If the contractor intends to subcontract work as part of its performance under this contract, the contractor shall include in the proposal a plan to subcontract to small, women-owned, minority-owned, and service disabled veteran-owned businesses."
"Employment services organization" means an organization that provides community-based employment services to individuals with disabilities that is an approved Commission on Accreditation of Rehabilitation Facilities (CARF) accredited vendor of the Department for Aging and Rehabilitative Services.
2. "Asian American" means a person having origins in any of the original peoples of the Far East, Southeast Asia, the Indian subcontinent, or the Pacific Islands, including but not limited to Japan, China, Vietnam, Samoa, Laos, Cambodia, Taiwan, Northern Mariana Islands, the Philippines, a U.S. territory of the Pacific, India, Pakistan, Bangladesh, or Sri Lanka and who is regarded as such by the community of which this person claims to be a part.
"Minority-owned business" means a business that is at least 51 percent owned by one or more minority individuals who are U.S. citizens or legal resident aliens, or in the case of a corporation, partnership, or limited liability company or other entity, at least 51 percent of the equity ownership interest in the corporation, partnership, or limited liability company or other entity is owned by one or more minority individuals who are U.S. citizens or legal resident aliens, and both the management and daily business operations are controlled by one or more minority individuals, or any historically black college or university as defined in § 2.2-1604, regardless of the percentage ownership by minority individuals or, in the case of a corporation, partnership, or limited liability company or other entity, the equity ownership interest in the corporation, partnership, or limited liability company or other entity.
"Service disabled veteran business" means a business that is at least 51 percent owned by one or more service disabled veterans or, in the case of a corporation, partnership, or limited liability company or other entity, at least 51 percent of the equity ownership interest in the corporation, partnership, or limited liability company or other entity is owned by one or more individuals who are service disabled veterans and both the management and daily business operations are controlled by one or more individuals who are service disabled veterans.
"Women-owned business" means a business that is at least 51 percent owned by one or more women who are U.S. citizens or legal resident aliens, or in the case of a corporation, partnership, or limited liability company or other entity, at least 51 percent of the equity ownership interest is owned by one or more women who are U.S. citizens or legal resident aliens, and both the management and daily business operations are controlled by one or more women.
1982, c. 647, §§ 11-44, 11-48; 1984, c. 279; 2000, c. 628; 2001, c. 844; 2003, c. 226; 2004, cc. 865, 891; 2006, cc. 831, 921; 2007, c. 787; 2008, cc. 521, 767; 2009, c. 869; 2013, c. 482; 2015, cc. 733, 765, 775; 2016, c. 525; 2017, cc. 397, 407, 578.
§ 2.2-4310.3. Fiscal data pertaining to certain enhancement or remedial measures.
The Department of General Services shall make available a dashboard of purchase order reports from the Commonwealth's statewide electronic procurement system known as eVA. The dashboard shall include aggregated data showing (i) current fiscal year purchase orders, (ii) purchase orders from the previous fiscal year, and (iii) other relevant data derived from any enhancement or remedial measure implemented by the Governor pursuant to subsection C of § 2.2-4310.
2016, c. 578.
§ 2.2-4311.1. Compliance with federal, state, and local laws and federal immigration law; required contract provisions.
All public bodies shall provide in every written contract that the contractor does not, and shall not during the performance of the contract for goods and services in the Commonwealth, knowingly employ an unauthorized alien as defined in the federal Immigration Reform and Control Act of 1986.
2008, cc. 598, 702.
§ 2.2-4313. Petition for recycled goods and products; periodic review of procurement standards.
A. Any person who believes that particular goods or products with recycled content are functionally equivalent to the same goods or products produced from virgin materials may petition the Department of General Services or other appropriate agency of the Commonwealth to include the recycled goods or products in its procurement process. The petitioner shall submit, prior to or during the procurement process, documentation that establishes that the goods or products (i) contain recycled content and (ii) can meet the performance standards set forth in the applicable specifications. If the Department of General Services or other agency of the Commonwealth that receives the petition determines that the documentation demonstrates that the goods or products with recycled content will meet the performance standards set forth in the applicable specifications, it shall incorporate the goods or products into its procurement process.
B. The Department of General Services and all agencies of the Commonwealth shall review and revise their procurement procedures and specifications on a continuing basis to encourage the use of goods and products with recycled content and shall, in developing new procedures and specifications, encourage the use of goods and products with recycled content.
1993, c. 223, § 11-41.01; 2001, c. 844.
§ 2.2-4316. Comments concerning specifications.
1982, c. 647, § 11-50; 2001, c. 844.
At least 30 days prior to the date established for submission of bids or proposals under the procurement of the contract for which the prequalification applies, the public body shall advise in writing each contractor who submitted an application whether that contractor has been prequalified. In the event that a contractor is denied prequalification, the written notification to the contractor shall state the reasons for the denial of prequalification and the factual basis of such reasons.
1982, c. 647, § 11-53; 2001, c. 844.
§ 2.2-4320. Exclusion of insurance bids prohibited.
Notwithstanding any other provision of law, no insurer licensed to transact the business of insurance in the Commonwealth or approved to issue surplus lines insurance in the Commonwealth shall be excluded from presenting an insurance bid proposal to a public body in response to a request for proposal or an invitation to bid. Nothing in this section shall preclude a public body from debarring a prospective insurer pursuant to § 2.2-4321.
1996, c. 989, § 11-44.1; 2001, c. 844.
§ 2.2-4321.1. Prohibited contracts; exceptions; determination by Department of Taxation; appeal; remedies.
A. No state agency shall contract for goods or services with a nongovernmental source if the source, or any affiliate of the source, is subject to the provisions of (i) § 58.1-612 and fails or refuses to collect and remit the tax on its sales delivered by any means to locations within the Commonwealth or (ii) Article 2 (§ 58.1-320 et seq.) or Article 10 (§ 58.1-400 et seq.) of Chapter 3 of Title 58.1 and fails or refuses to remit any tax due thereunder. The provisions of clause (ii) shall not apply to any person that has (a) entered into a payment agreement with the Department of Taxation to pay the tax and is not delinquent under the terms of the agreement or (b) appealed the assessment of the tax in accordance with law and such appeal is pending.
B. A state agency may contract for goods or services with a source prohibited under subsection A in the event of an emergency or where the nongovernmental source is the sole source of such goods or services.
C. The determination of whether a source is a prohibited source shall be made by the Department of Taxation after providing the prohibited source with notice and an opportunity to respond to the proposed determination. The Department of Taxation shall notify the Department of General Services of its determination.
D. The Department of General Services shall post public notice of all prohibited sources on its public internet procurement website and on other appropriate websites.
E. The remedies provided in Article 5 (§ 2.2-4357 et seq.) of this chapter shall not apply to any determination made pursuant to this section and the sole remedy for any adverse determination shall be as provided in subsection F.
F. Any source aggrieved by a determination of the Department of Taxation made under this section may apply to the Tax Commissioner for correction of the determination. The Tax Commissioner shall respond within 30 days of receipt of the application for corrective action. Within 10 days after receipt of the Tax Commissioner's response, the aggrieved source may appeal to the Circuit Court for the City of Richmond. If it is determined that the determination of the Department of Taxation was arbitrary, capricious, or not in accordance with law, the sole relief shall be restoration of the source's eligibility to contract with state agencies. No claim for damages or attorney's fees shall be awarded.
G. Any action of the Department of Taxation, the Department of General Services, or of any state agency under this section shall be exempt from the provisions of the Administrative Process Act (§ 2.2-4000 et seq.).
H. For the purposes of this section, "state agency" means any authority, board, department, instrumentality, institution, agency or other unit of state government. State agency shall not include any public institution of higher education or any county, city or town or any local or regional governmental authority.
2003, cc. 994, 1006; 2006, c. 408.
§ 2.2-4328. Preference for local products and firms; applicability.
A. The governing body of a county, city or town may, in the case of a tie bid, give preference to goods, services and construction produced in such locality or provided by persons, firms or corporations having principal places of business in the locality, if such a choice is available; otherwise the tie shall be decided by lot, unless § 2.2-4324 applies.
B. The provisions of this section shall apply only to bids submitted pursuant to a written Invitation to Bid.
1994, c. 882, § 11-47.4; 2001, c. 844.
B. For nontransportation-related construction contracts in excess of $100,000 but less than $500,000, where the bid bond requirements are waived, prospective contractors shall be prequalified for each individual project in accordance with § 2.2-4317. However, a locality may waive the requirement for prequalification of a bidder with a current Class A contractor license for contracts in excess of $100,000 but less than $300,000 upon a written determination made in advance by the local governing body that waiving the requirement is in the best interests of the locality. A locality shall not enter into more than 10 such contracts per year.
§ 2.2-4337. Performance and payment bonds.
§ 2.2-4339. Bonds on other than construction contracts.
A public body may require bid, payment, or performance bonds for contracts for goods or services if provided in the Invitation to Bid or Request for Proposal.
1982, c. 647, § 11-62; 2001, c. 844.
Article 3. Exemptions and Limitations.
1982, c. 647, §§ 11-35, 11-39, 11-40; 1983, c. 593; 1984, cc. 159, 330, 764, § 11-40.2; 1985, c. 74; 1986, cc. 149, 212, 559; 1987, c. 583; 1991, c. 645; 1994, cc. 661, 918; 1995, c. 18; 1996, cc. 261, 280, 683, 1019; 1997, cc. 85, 488, 785, 861, 863; 1998, cc. 121, 132; 1999, cc. 230, 248, 735, 910, § 11-40.4; 2000, cc. 29, 382, 400, 642, 644, 666, 703; 2001, cc. 392, 409, 736, 753, 774, 844; 2002, cc. 87, 478, 491, 582, 595; 2003, cc. 226, 1008; 2004, cc. 145, 865, 891; 2006, c. 656; 2007, cc. 434, 697; 2008, c. 184; 2009, cc. 737, 767; 2010, c. 694; 2011, c. 23; 2012, cc. 803, 805, 835, 836; 2013, cc. 583, 762, 794; 2015, cc. 760, 776; 2016, cc. 296, 465; 2017, cc. 87, 625, 699, 704.
§ 2.2-4343.1. Permitted contracts with certain religious organizations; purpose; limitations.
A. It is the intent of the General Assembly, in accordance with the Personal Responsibility and Work Opportunity Reconciliation Act of 1996, P.L. 104-193, to authorize public bodies to enter into contracts with faith-based organizations for the purposes described in this section on the same basis as any other nongovernmental source without impairing the religious character of such organization, and without diminishing the religious freedom of the beneficiaries of assistance provided under this section.
B. For the purposes of this section, "faith-based organization" means a religious organization that is or applies to be a contractor to provide goods or services for programs funded by the block grant provided pursuant to the Personal Responsibility and Work Opportunity Reconciliation Act of 1996, P.L. 104-193.
C. Public bodies, in procuring goods or services, or in making disbursements pursuant to this section, shall not (i) discriminate against a faith-based organization on the basis of the organization's religious character or (ii) impose conditions that (a) restrict the religious character of the faith-based organization, except as provided in subsection F, or (b) impair, diminish, or discourage the exercise of religious freedom by the recipients of such goods, services, or disbursements.
D. Public bodies shall ensure that all invitations to bid, requests for proposals, contracts, and purchase orders prominently display a nondiscrimination statement indicating that the public body does not discriminate against faith-based organizations.
E. A faith-based organization contracting with a public body (i) shall not discriminate against any recipient of goods, services, or disbursements made pursuant to a contract authorized by this section on the basis of the recipient's religion, religious belief, refusal to participate in a religious practice, or on the basis of race, age, color, gender or national origin and (ii) shall be subject to the same rules as other organizations that contract with public bodies to account for the use of the funds provided; however, if the faith-based organization segregates public funds into separate accounts, only the accounts and programs funded with public funds shall be subject to audit by the public body. Nothing in clause (ii) shall be construed to supersede or otherwise override any other applicable state law.
F. Consistent with the Personal Responsibility and Work Opportunity Reconciliation Act of 1996, P.L. 104-193, funds provided for expenditure pursuant to contracts with public bodies shall not be spent for religious worship, instruction, or proselytizing; however, this prohibition shall not apply to expenditures pursuant to contracts, if any, for the services of chaplains.
G. Nothing in this section shall be construed as barring or prohibiting a faith-based organization from any opportunity to make a bid or proposal or contract on the grounds that the faith-based organization has exercised the right, as expressed in 42 U.S.C. (§ 2000 e-1 et seq.), to employ persons of a particular religion.
H. If an individual, who applies for or receives goods, services, or disbursements provided pursuant to a contract between a public body and a faith-based organization, objects to the religious character of the faith-based organization from which the individual receives or would receive the goods, services, or disbursements, the public body shall offer the individual, within a reasonable period of time after the date of his objection, access to equivalent goods, services, or disbursements from an alternative provider.
The public body shall provide to each individual who applies for or receives goods, services, or disbursements provided pursuant to a contract between a public body and a faith-based organization a notice in bold face type that states: "Neither the public body's selection of a charitable or faith-based provider of services nor the expenditure of funds under this contract is an endorsement of the provider's charitable or religious character, practices, or expression. No provider of services may discriminate against you on the basis of religion, a religious belief, or your refusal to actively participate in a religious practice. If you object to a particular provider because of its religious character, you may request assignment to a different provider. If you believe that your rights have been violated, please discuss the complaint with your provider or notify the appropriate person as indicated in this form."
2001, c. 774, § 11-35.1; 2005, c. 928.
4. (Effective until January 15, 2018) The Department of Alcoholic Beverage Control for the purchase of alcoholic beverages.
4. (Effective January 15, 2018) The Virginia Alcoholic Beverage Control Authority for the purchase of alcoholic beverages.
Article 4. Prompt Payment.
§ 2.2-4347. Definitions.
"Contractor" means the entity that has a direct contract with any "state agency" as defined herein, or any agency of local government as discussed in § 2.2-4352.
"Debtor" means any individual, business, or group having a delinquent debt or account with any state agency that obligation has not been satisfied or set aside by court order or discharged in bankruptcy.
"Payment date" means either (i) the date on which payment is due under the terms of a contract for provision of goods or services; or (ii) if such date has not been established by contract, (a) thirty days after receipt of a proper invoice by the state agency or its agent or forty-five days after receipt by the local government or its agent responsible under the contract for approval of such invoices for the amount of payment due, or (b) thirty days after receipt of the goods or services by the state agency or forty-five days after receipt by the local government, whichever is later.
"State agency" means any authority, board, department, instrumentality, institution, agency or other unit of state government. The term shall not include any county, city or town or any local or regional governmental authority.
1984, c. 736, § 11-62.1; 1990, c. 824; 1992, c. 75; 2001, c. 844.
§ 2.2-4349. Retainage to remain valid.
1984, c. 736, § 11-62.8; 2001, c. 844.
§ 2.2-4350. Prompt payment of bills by state agencies.
1984, c. 736, §§ 11-62.2, 11-62.3; 1992, c. 75; 2001, c. 844.
§ 2.2-4352. Prompt payment of bills by localities.
1985, c. 454, § 11-62.10; 2001, c. 844.
§ 2.2-4353. Date of postmark deemed to be date payment is made.
1984, c. 736, § 11-62.6; 2001, c. 844.
§ 2.2-4355. Interest penalty; exceptions.
E. Notwithstanding subsection A, no interest penalty shall be paid to any debtor on any payment, or portion thereof, withheld pursuant to the Comptroller's Debt Setoff Program, as authorized by the Virginia Debt Collection Act (§ 2.2-4800 et seq.), commencing with the date the payment is withheld. If, as a result of an error, a payment or portion thereof is withheld, and it is determined that at the time of setoff no debt was owed to the Commonwealth, then interest shall accrue at the rate determined pursuant to subsection B on amounts withheld that remain unpaid after seven days following the payment date.
1984, c. 736, § 11-62.5; 1985, c. 101; 1992, c. 75; 2001, c. 844.
Article 5. Remedies.
§ 2.2-4357. Ineligibility.
A. Any bidder, offeror or contractor refused permission to participate, or disqualified from participation, in public contracts shall be notified in writing. Prior to the issuance of a written determination of disqualification or ineligibility, the public body shall (i) notify the bidder in writing of the results of the evaluation, (ii) disclose the factual support for the determination, and (iii) allow the bidder an opportunity to inspect any documents that relate to the determination, if so requested by the bidder within five business days after receipt of the notice.
Within ten business days after receipt of the notice, the bidder may submit rebuttal information challenging the evaluation. The public body shall issue its written determination of disqualification or ineligibility based on all information in the possession of the public body, including any rebuttal information, within five business days of the date the public body received such rebuttal information.
If the evaluation reveals that the bidder, offeror or contractor should be allowed permission to participate in the public contract, the public body shall cancel the proposed disqualification action. If the evaluation reveals that the bidder should be refused permission to participate, or disqualified from participation, in the public contract, the public body shall so notify the bidder, offeror or contractor. The notice shall state the basis for the determination, which shall be final unless the bidder appeals the decision within ten days after receipt of the notice by invoking administrative procedures meeting the standards of § 2.2-4365, if available, or in the alternative by instituting legal action as provided in § 2.2-4364.
B. If, upon appeal, it is determined that the action taken was arbitrary or capricious, or not in accordance with the Constitution of Virginia, applicable state law or regulations, the sole relief shall be restoration of eligibility.
1982, c. 647, § 11-63; 1998, c. 753; 2001, c. 844.
§ 2.2-4361. Effect of appeal upon contract.
Pending final determination of a protest or appeal, the validity of a contract awarded and accepted in good faith in accordance with this chapter shall not be affected by the fact that a protest or appeal has been filed.
1982, c. 647, § 11-67; 2001, c. 844.
§ 2.2-4362. Stay of award during protest.
An award need not be delayed for the period allowed a bidder or offeror to protest, but in the event of a timely protest as provided in § 2.2-4360, or the filing of a timely legal action as provided in § 2.2-4364, no further action to award the contract shall be taken unless there is a written determination that proceeding without delay is necessary to protect the public interest or unless the bid or offer would expire.
1982, c. 647, § 11-68; 1997, c. 864; 2001, c. 844.
§ 2.2-4363. Contractual disputes.
A. Contractual claims, whether for money or other relief, shall be submitted in writing no later than 60 days after final payment. However, written notice of the contractor's intention to file a claim shall be given at the time of the occurrence or beginning of the work upon which the claim is based. Nothing herein shall preclude a contract from requiring submission of an invoice for final payment within a certain time after completion and acceptance of the work or acceptance of the goods. Pendency of claims shall not delay payment of amounts agreed due in the final payment.
1. Contractual claims, whether for money or other relief, shall be submitted in writing no later than 60 days after receipt of final payment; however, written notice of the contractor's intention to file a claim shall be given at the time of the occurrence or at the beginning of the work upon which the claim is based.
2. No written decision denying a claim or addressing issues related to the claim shall be considered a denial of the claim unless the written decision is signed by the public body's chief administrative officer or his designee. The contractor may not institute legal action prior to receipt of the final written decision on the claim unless the public body fails to render a decision within 90 days of submission of the claim. Failure of the public body to render a decision within 90 days shall not result in the contractor being awarded the relief claimed or in any other relief or penalty. The sole remedy for the public body's failure to render a decision within 90 days shall be the contractor's right to institute immediate legal action.
D. A contractor may not invoke administrative procedures meeting the standards of § 2.2-4365, if available, or institute legal action as provided in § 2.2-4364, prior to receipt of the public body's decision on the claim, unless the public body fails to render such decision within the time specified in the contract or, if no time is specified, then within the time provided by subsection C. A failure of the public body to render a final decision within the time provided in subsection C shall be deemed a final decision denying the claim by the public body.
Article 6. Ethics in Public Contracting.
§ 2.2-4369. Proscribed participation by public employees in procurement transactions.
Except as may be specifically allowed by subdivisions B 1, 2, and 3 of § 2.2-3112, no public employee having official responsibility for a procurement transaction shall participate in that transaction on behalf of the public body when the employee knows that:
1982, c. 647, § 11-74; 1985, c. 565; 1987, Sp. Sess., c. 1; 1997, c. 83; 2001, c. 844; 2003, c. 694; 2017, cc. 829, 832.
§ 2.2-4370. Disclosure of subsequent employment.
No public employee or former public employee having official responsibility for procurement transactions shall accept employment with any bidder, offeror or contractor with whom the employee or former employee dealt in an official capacity concerning procurement transactions for a period of one year from the cessation of employment by the public body unless the employee or former employee provides written notification to the public body, or a public official if designated by the public body, or both, prior to commencement of employment by that bidder, offeror or contractor.
1982, c. 647, § 11-76; 2001, c. 844.
§ 2.2-4371. Prohibition on solicitation or acceptance of gifts; gifts by bidders, offerors, contractor or subcontractors prohibited.
A. No public employee having official responsibility for a procurement transaction shall solicit, demand, accept, or agree to accept from a bidder, offeror, contractor or subcontractor any payment, loan, subscription, advance, deposit of money, services or anything of more than nominal or minimal value, present or promised, unless consideration of substantially equal or greater value is exchanged. The public body may recover the value of anything conveyed in violation of this subsection.
B. No bidder, offeror, contractor or subcontractor shall confer upon any public employee having official responsibility for a procurement transaction any payment, loan, subscription, advance, deposit of money, services or anything of more than nominal value, present or promised, unless consideration of substantially equal or greater value is exchanged.
1982, c. 647, §§ 11-75, 11-77; 2001, c. 844.
§ 2.2-4372. Kickbacks.
A. No contractor or subcontractor shall demand or receive from any of his suppliers or his subcontractors, as an inducement for the award of a subcontract or order, any payment, loan, subscription, advance, deposit of money, services or anything, present or promised, unless consideration of substantially equal or greater value is exchanged.
B. No subcontractor or supplier shall make, or offer to make, kickbacks as described in this section.
C. No person shall demand or receive any payment, loan, subscription, advance, deposit of money, services or anything of value in return for an agreement not to compete on a public contract.
D. If a subcontractor or supplier makes a kickback or other prohibited payment as described in this section, the amount thereof shall be conclusively presumed to have been included in the price of the subcontract or order and ultimately borne by the public body and shall be recoverable from both the maker and recipient. Recovery from one offending party shall not preclude recovery from other offending parties.
1982, c. 647, § 11-78; 2001, c. 844.
§ 2.2-4373. Participation in bid preparation; limitation on submitting bid for same procurement.
1997, c. 68, § 11-78.1; 2001, c. 844.
§ 2.2-4374. Purchase of building materials, etc., from architect or engineer prohibited.
A. No building materials, supplies or equipment for any building or structure constructed by or for a public body shall be sold by or purchased from any person employed as an independent contractor by the public body to furnish architectural or engineering services, but not construction, for such building or structure or from any partnership, association or corporation in which such architect or engineer has a personal interest as defined in § 2.2-3101.
B. No building materials, supplies or equipment for any building or structure constructed by or for a public body shall be sold by or purchased from any person who has provided or is currently providing design services specifying a sole source for such materials, supplies or equipment to be used in the building or structure to the independent contractor employed by the public body to furnish architectural or engineering services in which such person has a personal interest as defined in § 2.2-3101.
C. The provisions of subsections A and B shall not apply in cases of emergency or for transportation-related projects conducted by the Department of Transportation or the Virginia Port Authority.
1982, c. 647, § 11-79; 1993, c. 202; 1994, c. 882; 1996, c. 827; 2001, c. 844.
§ 2.2-4375. Certification of compliance required; penalty for false statements.
B. Any public employee required to submit a certification as provided in subsection A who knowingly makes a false statement in the certification shall be punished as provided in § 2.2-4377.
1992, c. 761, § 11-79.1; 2001, c. 844.
§ 2.2-4376. Misrepresentations prohibited.
No public employee having official responsibility for a procurement transaction shall knowingly falsify, conceal, or misrepresent a material fact; knowingly make any false, fictitious or fraudulent statements or representations; or make or use any false writing or document knowing it to contain any false, fictitious or fraudulent statement or entry.
1992, c. 761, § 11-79.2; 2001, c. 844.