Source: http://docplayer.net/21028681-Contract-for-the-appointment-of-an-approved-inspector.html
Timestamp: 2018-12-11 02:36:27
Document Index: 665306966

Matched Legal Cases: ['ART 1', 'ART 2', 'ART 3', 'ART 4', 'art 2', 'art 2', 'ART 1', 'ART 2', 'ART 3', 'art 2', 'ART 4', 'art 2', 'art 2', 'art 1', 'art 2', 'art 3', 'art 2']

CONTRACT FOR THE APPOINTMENT OF AN APPROVED INSPECTOR - PDF
Download "CONTRACT FOR THE APPOINTMENT OF AN APPROVED INSPECTOR"
1 CONTRACT FOR THE APPOINTMENT OF AN APPROVED INSPECTOR CIC/AppInsp The Construction Industry Council - Association of Consultant Approved Inspectors contract for the appointment of an approved inspector under the Building Act 1984
2 CONTRACT FOR THE APPOINTMENT OF AN APPROVED INSPECTOR CIC/AppInsp The Construction Industry Council - Association of Consultant Approved Inspectors contract for the appointment of an approved inspector under the Building Act 1984 Full members of the Construction Industry Council Association of Building Engineers Association of Consultant Architects Association of Consultant Approved Inspectors Association for Consultancy and Engineering Association for Project Management Association for Project Safety British Institute of Facilities Management British Institute of Interior Design Building Research Establishment Building Services Research and Information Association Chartered Institute of Architectural Technologists Chartered Institution of Building Services Engineers Chartered Institute of Building Chartered Institution of Highways & Transportation Chartered Institute of Plumbing and Heating Engineering Construction Industry Research and Information Association Consultant Quantity Surveyors Association Ground Forum The Higher Education Academy (Built Environment Discipline) Institution of Civil Engineers Chartered Institution of Civil Engineering Surveyors Institute of Clerks of Works and Construction Inspectorate Institute of Highway Engineers Institute of Specialist Surveyors and Engineers Institution of Structural Engineers Local Authority Building Control Landscape Institute National House-Building Council Royal Institute of British Architects Royal Institution of Chartered Surveyors Royal Town Planning Institute Associate members Adjudication Society British Association of Construction Heads British Board of Agrément British Standards Institute Chartered Institute of Marketing (Construction Industry Group) Conference on Training in Architectural Conservation Construction Youth Trust National Housing Federation Society of Construction Law SPONGE UK Green Building Council
3 The Association of Consultant Approved Inspectors (ACAI) is the body that represents the interests of private sector building control. The Construction Industry Council is a body designated to approve inspectors under the Building Act 1984 and regulations made under it. Construction Industry Council 2013 Construction Industry Council 26 Store Street, London WC1E 7BT tel , fax ISBN When a contract has been concluded, the parties and their advisers may photocopy the signed contract for their use. In all other cases, it is an infringement of copyright to reproduce, store in a retrieval system or transmit in any form or by any means (electronic, mechanical, photocopying, recording or otherwise) any part of this document, without the prior permission of the publisher. Infringement is actionable under the Copyright, Designs and Patents Act First edition published March 2009 Second edition published May 2013 The publisher makes every effort to ensure the accuracy and quality of information when it is published. However, it can take no responsibility for the subsequent use of this information, nor for any errors or omissions that it may contain. Design by Astwood Design Consultancy Printed in Great Britain
4 APPROVED INSPECTOR CONTRACT CIC/AppInsp FORM OF AGREEMENT... 2 TERMS AND CONDITIONS... 4 PART 1: CONTRACT DETAILS AND FEE... 4 PART 2: SERVICES... 6 PART 3: CONDITIONS Approved Inspector s general obligations Client s information and obligations Design, permits and approvals Compliance with Building Regulations Payment Changes to the Project and Additional Work Insurance Assignment and subcontracting Termination and discharge Termination and discharge (continued) Termination and discharge (continued) Consequences of termination Limitations of liability Notices Disputes and complaints Novation Rights of third parties Commencement PART 4: DEFINITIONS AND INTERPRETATION GUIDANCE Construction Industry Council
5 CIC/AppInsp APPROVED INSPECTOR CONTRACT FORM OF AGREEMENT THIS CONTRACT is made the. day of Between 1. The Client Insert name of Client whose address/registered office is at and 2. The Approved Inspector Insert name of Approved Inspector whose address/registered office is at Whereas... The Client wishes to appoint the Approved Inspector as an approved inspector under the Building Act 1984 in connection with at Insert details of work and name of Project ( the Project ) and the Approved Inspector has agreed to provide the Services for the Project on the terms set out in this contract. 2 Construction Industry Council 2013
6 APPROVED INSPECTOR CONTRACT CIC/AppInsp It is agreed That under this contract, which comprises this Form of Agreement and the attached Terms and Conditions in four Parts: 1. The Approved Inspector shall perform the Services set out in Part 2: Services and Additional Work (if any) in accordance with the terms of this contract. If there is any conflict between the Statutory Functions and the other services listed in Part 2: Services, the Statutory Functions shall prevail. 2. The Client shall pay the Approved Inspector for the Services and the performance of any Additional Work in accordance with the terms of this contract. 3. This contract is subject to the law of England and Wales and the Client and the Approved Inspector submit to the jurisdiction of the courts of England and Wales. As witness the hands of the parties hereto Signed by or on behalf of the Approved Inspector 4 Name and signature of Approved Inspector or person signing on behalf of Approved Inspector Signed by or on behalf of the Client 5 Name and signature of Client or person signing on behalf of Client Construction Industry Council
7 CIC/AppInsp APPROVED INSPECTOR CONTRACT TERMS AND CONDITIONS PART 1: CONTRACT DETAILS AND FEES 1 1 The Client has appointed the following to undertake the following roles: 6 6 Insert details as appropriate Architectural design:... Civil and structural design:... Building services design:... Contractor:... Others: The Client is / is not a domestic client The anticipated project period up to practical completion of the construction work is 7 Delete as appropriate; a domestic client is one or more individuals who are owners or occupiers of a dwelling The company providing professional indemnity insurance in accordance with clause 3 7 is The total limit of the Approved Inspector s liability to the Client referred to in clause This information is required by the CIC Code of Conduct for Approved Inspectors, available at is 1 6 The provisions for novation in clause 3 16 shall / shall not apply. 9 9 Delete as appropriate (see Guidance paragraph 9) 1 7 The Fee The Fee shall be charged on a lump sum/time charge basis Lump sum: The Fee shall be the lump sum of 10 Delete as appropriate 11 Delete or insert details as appropriate Construction Industry Council 2013
8 APPROVED INSPECTOR CONTRACT CIC/AppInsp 12 If the Fee is charged on a lump sum basis, delete the word 'Fee'. In any event, insert details as appropriate: Additional Work is charged on a time basis, see clause Time charges: The Fee/charge for Additional Work shall be calculated on the basis of the time properly and necessarily spent by the Approved Inspector in performing the Services at the following rates: per hour per hour per hour per hour. 1 8 Expenses and disbursements 13 Also known as building guarantee insurance 14 Delete the alternatives which do not apply / insert details as appropriate If warranty insurance 13 is required (in the case of new homes) this shall be a disbursement additional to the Fee. 14 All other expenses and disbursements, incurred by the Approved Inspector in performing the Services and any Additional Work, are included in the Fee; or The Approved Inspector shall be entitled to charge for his expenses and disbursements; or The Approved Inspector shall be entitled to charge for the following expenses and disbursements: 1 9 Instalment payments Payment shall be made by instalments as follows: 15 Insert details as appropriate eg last day of each month, completion of specific stages 16 If time charge applies, insert Time Instalment date, stage or milestone 15 Amount or % or time Construction Industry Council
9 CIC/AppInsp APPROVED INSPECTOR CONTRACT PART 2: SERVICES Taking such steps as are reasonable to enable him to be satisfied within the limits of the professional skill and care set out in clause 3 1 that the plans and the works comply with the Building Regulations, the Approved Inspector shall - 17 either undertake the Statutory Functions. or undertake the following services (where appropriate to the Project), including the Statutory Functions: 17 Delete as appropriate Instructions Initial notice Assessment of plans Statutory consultations Plans certificate Inspection notification framework 18 Receive instructions, brief and necessary documentation from the Client. Advise on procedure and programme for Building Regulation certification. Submit an initial notice(s) to relevant local authorities, and copy to the Client. Undertake an assessment of plans 19 for compliance and communicate to the Client observed non-compliance with the Building Regulations, conditions pertaining to the approval or passing of plans and remedies available in the event of a dispute over compliance. Maintain appropriate records of the design assessment process. Consult with the fire authority and forward observations to the Client. Undertake all other statutory consultations and forward observations of consultees to the Client. Consider the desirability of undertaking additional consultations and communicate to the Client any consultees observations or advice beyond the scope of the Building Regulations. Alert the Client to provisions of legislation outside the Building Regulations believed to be relevant. If requested by the Client, when satisfied that the plans show no observed contraventions of the Building Regulations, issue a plans certificate. Compile a schedule of modifications specified and/or further plans or information required to demonstrate compliance of plans. Prepare an inspection notification framework (INF) and if requested provide a copy to the Client. Adopt an appropriate site inspection regime taking account of relevant factors, and keep under review. Make inspections of the site to observe compliance with the Building Regulations. 18 Delete any services not to be undertaken 19 plans is defined by the Building Act 1984 S126 as including drawings of any other description, specifications and other information in any form 6 Construction Industry Council 2013
10 APPROVED INSPECTOR CONTRACT CIC/AppInsp Final certificate Maintain appropriate records of site inspections, identifying the work inspected and any observed non-compliance. Communicate any observed contraventions of Building Regulations. Notify observed significant departures from plans to consultees. Consider the need for tests, throughout construction and at completion, inform the Client of the requirements; witness tests and receive certificates as appropriate. Request copies of such plans as are necessary in relation to the commissioning of services prior to issue of a final certificate(s). Having taken reasonable steps to be satisfied that the whole or part of the works has been completed for Building Regulations purposes, issue a final certificate(s) and send to the Client. If requested by the Client, provide a list of inspections carried out. Retain statutory records for an appropriate period. References to the Client include persons designated by the Client. 20 Tick any services to be undertaken 20 The Approved Inspector shall undertake the following additional services: Assist with negotiations and applications for approvals under local Acts. Attend design team meetings, as agreed. Undertake further consultations, as agreed. Attend site meetings, as agreed. Make further inspections of the site over and above those identified in the INF, as agreed. Witness tests outside the site, as agreed. Participate in assessing plans by electronic means (such as web collaboration tools or building information modelling). Assist with advice on need for specialist studies and surveys of site. 21 Add additional services as required Construction Industry Council
11 CIC/AppInsp APPROVED INSPECTOR CONTRACT PART 3: CONDITIONS 3 1 Approved Inspector s general obligations The Approved Inspector shall carry out the Services and any Additional Work with reasonable skill, care and diligence in accordance with this contract. The Approved Inspector shall have due regard to the CIC Code of Conduct for Approved Inspectors and where possible to any programme for the Project (as amended from time to time). 3 2 Client s information and obligations The Client shall provide such information and assistance as the Approved Inspector reasonably requires from time to time in order to facilitate the timely provision of the Services and any Additional Work The Client shall be responsible for safe access to the Project being provided when the Approved Inspector reasonably requires it. 3 3 Design, permits and approvals Except where permitted by law 22 and to the extent set out in Part 2: Services, the Client shall be entirely responsible for the design, construction and management of the Project and any Additional Work The Client shall also be entirely responsible for obtaining and implementing all necessary permits, licences and approvals, except those which form part of the Services or any Additional Work. 22 In the case of a domestic client, under Regulation 10 of The Building (Approved Inspectors etc) Regulations 2000, the Approved Inspector may be responsible for some elements of design or construction 3 4 Compliance with Building Regulations The Client shall be responsible for the Project s compliance with the Building Regulations and the Services do not include advising the Client or managing the Project to ensure that compliance is achieved The Approved Inspector shall take such steps as are reasonable to enable it to be satisfied as to the Project s compliance with the Building Regulations, and if so satisfied, it shall issue a final certificate. The final certificate is not a representation that every aspect of the Project complies with the Building Regulations. 3 5 Payment The due date for payment of an instalment of the Fee, together with expenses and disbursements if they are to be paid in addition, shall be the date of submission of the Approved Inspector s valid invoice for each instalment. The final date for payment of that invoice is 28 days after the due date for payment. The Fee is exclusive of VAT, which shall be paid in addition if applicable. 8 Construction Industry Council 2013
12 APPROVED INSPECTOR CONTRACT CIC/AppInsp 23 Does not apply in the case of a domestic client 23[Any sum due under this contract which is not paid by the final date for payment shall carry interest at 5% above the Bank of England official dealing rate applicable from the final date for payment until the date on which payment is made.] 3 6 Changes to the Project and Additional Work The Approved Inspector shall notify the Client in writing as soon as it becomes aware that any Additional Work will be required, because of: Changes in the design, size, scope or complexity of the Project; Changes in the timing or programming of the Project; A failure by the Client to comply with its obligations under this contract; Additional meetings and/or visits and/or other work is required. The Client shall pay the Approved Inspector for the Additional Work on a time charge basis, at the rates set out in clause 1 7. The Approved Inspector may include the charge in the next payment instalment after the Additional Work (or part of it) has been performed. 3 7 Insurance 24 That is, a scheme approved by the Secretary of State under the Building Act 1984 S47(6) The Approved Inspector shall maintain professional indemnity insurance and public liability insurance in compliance with the guidelines issued by the Department for Communities and Local Government (or any successor Department responsible for the Building Act 1984). 24 On the Client s written request, the Approved Inspector shall provide evidence that these insurances are being properly maintained. 3 8 Assignment and subcontracting Either party may assign its rights and benefits under this contract. The Approved Inspector may subcontract any part of the Services and any Additional Work, with the prior approval of the Client, not to be unreasonably withheld or delayed. 3 9 Termination and discharge The Client may terminate this contract forthwith if: The Approved Inspector is in material breach of its obligations under this contract and has failed to remedy the breach within 28 days of the date of a notice of the breach from the Client; or The Approved Inspector becomes insolvent. Construction Industry Council
13 CIC/AppInsp APPROVED INSPECTOR CONTRACT 3 10 The Approved Inspector may terminate this contract forthwith if: The Client is in material breach of its obligations under this contract and has failed to remedy the breach within 28 days of the date of a notice of the breach from the Approved Inspector; The Approved Inspector reasonably believes that it will not be in a position to issue a final certificate on completion; or The Client becomes insolvent Following termination by the Approved Inspector or the Client, the Approved Inspector is entitled to write to the Local Authority (with a copy to the Client) cancelling the initial notice under the Building Regulations, in which case the approved inspector functions will revert to the Local Authority and the Approved Inspector will be discharged from all requirements to complete the Services or any Additional Work. The right of either party to terminate for material breach of this contract shall lapse if it has not been exercised within 35 days after giving notice of the breach to the other party Consequences of termination If this contract has been terminated, the Client shall pay the Approved Inspector any instalments of the Fee due up to the date of termination together with a fair and reasonable proportion of the next instalment of the Fee commensurate with the Services and any Additional Work performed by the Approved Inspector prior to the notice of termination. Termination of this contract shall not affect any rights or remedies of the Client or the Approved Inspector which exist at the date of termination Limitations of liability Nothing in this clause 3 13 shall limit the Approved Inspector s liability for negligence resulting in death or personal injury. Subject to that: Notwithstanding any other provisions in this contract (apart from clause ), the Approved Inspector s total liability to the Client for any claims arising under or in connection with this contract (whether in contract, in tort (including negligence), for breach of statutory duty or otherwise) shall be limited to the amount set out in clause Without prejudice to any other exclusion or limitation of liability, damages, loss, expense or costs, the liability of the Approved Inspector for any loss or damage ( the loss or damage ) under this contract shall be limited to that proportion as it would be just and equitable for the 10 Construction Industry Council 2013
14 APPROVED INSPECTOR CONTRACT CIC/AppInsp Approved Inspector to pay having regard to the extent of its responsibility for the loss or damage and on the assumptions that: all other consultants, contractors, subcontractors, and advisers engaged in connection with the Project have provided contractual undertakings on terms no less onerous than those in clause 3 1 to the Client in respect of the carrying out of their obligations in connection with the Project. there are no exclusions of or limitations of liability nor joint insurance or co-insurance provisions between the Client and any other party referred to in this clause and any such other party who is responsible to any extent for the loss or damage is contractually liable to the Client for the loss or damage; and all the parties referred to in this clause have paid to the Client such proportion of the loss or damage which it would be just and equitable for them to pay having regard to the extent of their responsibility for the loss or damage The Approved Inspector shall not be responsible for the supervision of any contractor or subcontractor, nor shall the Approved Inspector have any liability for ensuring the performance or adequate standard of workmanship of any contractor or subcontractor The Client shall look only to the Approved Inspector (and not to individuals engaged by the Approved Inspector or any individual directors or members of the Approved Inspector) for redress if the Client considers that there has been any breach of this contract. The Client agrees not to pursue any claims in contract, in tort (including negligence), for breach of statutory duty or otherwise against any such individuals as a result of carrying out its obligations under or in connection with this contract at any time. The Client acknowledges that such individuals are entitled to enforce this term of the contract pursuant to the Contracts (Rights of Third Parties) Act Notices The Client and the Approved Inspector can give notice to each other in writing under this contract by personal delivery. They can also give notice by Recorded Delivery or Special Delivery, in which case delivery is effective two working days after posting. Notices must be sent to the address on page 2 of this contract or any other address notified. Construction Industry Council
15 CIC/AppInsp APPROVED INSPECTOR CONTRACT 3 15 Disputes and complaints If the Client is not satisfied with the Approved Inspector s performance of the Services or any Additional Work, it may ask the Approved Inspector to implement the Approved Inspector s complaints handling procedure. The Approved Inspector shall provide a copy of the procedure on request. The operation of the Approved Inspector s complaints handling procedure does not affect the Client s right to refer a dispute to the courts [The Client and the Approved Inspector shall consider in good faith whether any dispute or difference between them is suitable for resolution by mediation, and if so shall take the appropriate steps with a view to resolving the dispute or difference by mediation.] [Either the Client or the Approved Inspector may at any time refer a dispute or difference arising under or in connection with this contract to adjudication in accordance with the edition of the CIC Model Adjudication Procedure current at the date of the adjudication notice. The Adjudicator shall be appointed by the CIC.] 25 Does not apply in the case of a domestic client 26 Does not apply in the case of a domestic client 3 16 Novation 27[The Approved Inspector shall, within 14 days of the Client s request, execute and deliver to the Client a novation agreement in favour of the contractor in the form published by the CIC current at the date of the Client s request (with the deletion of clause 4 and amending the recitals as appropriate). 27 Applies if so noted in clause 1 6 With effect from the date of execution of that novation agreement: all references to the Client in this contract shall (unless the context otherwise requires) be construed as references to the contractor; any variations to the Services and other obligations of the Client and the Approved Inspector set out in Schedules 1 and 2 to the novation agreement shall apply; and the rights and obligations of the Approved Inspector in respect of the Project shall otherwise remain unchanged.] 3 17 Rights of third parties No-one has any right to enforce any term of this contract under the Contracts (Rights of Third Parties) Act 1999, except as set out in clause This does not affect the rights of the Client and the Approved Inspector in relation to this contract Commencement Whatever the date of this contract, it shall have effect as if it had been signed on the date when the Approved Inspector commenced the Services. 12 Construction Industry Council 2013
16 APPROVED INSPECTOR CONTRACT CIC/AppInsp PART 4: DEFINITIONS AND INTERPRETATION 4 1 Definitions In this contract, unless the context otherwise requires, the following expressions have the following meanings: Additional Work means the type or volume of services appropriate for an Approved Inspector to carry out in relation to the Project as a result of or in consequence of the matters described in clause 3 6 and which are not already covered by the Services set out in Part 2, together with any other services instructed by the Client and agreed by the Approved Inspector. Approved Inspector means a licensed individual or organisation carrying out the duties given to an approved inspector by the Building Act 1984 and regulations made under it. CIC means the Construction Industry Council. Fee means the total amount to be paid to the Approved Inspector for the Services and any Additional Work. Services means the services listed in Part 2. Statutory Functions means the duties of an approved inspector under the Building Act 1984, regulations made under it and formal guidelines issued by a government department. 4 2 Interpretation In this contract, unless the context otherwise requires: the word include and any derivations of it shall be construed without limitation; the singular shall include the plural and vice versa; a gender shall include any other gender; and references to any statute or statutory instrument includes any statute or statutory instrument amending, consolidating or replacing it, and references to a statute includes statutory instruments and regulations made pursuant to it. Construction Industry Council
17 CIC/AppInsp APPROVED INSPECTOR CONTRACT GUIDANCE 1. These notes are for general guidance only and are not intended to affect the interpretation of the contract. Legal/professional advice should be sought to cover any particular situation. Completing the Form of Agreement 2. The form should be completed as follows: On page 2, in the Form of Agreement, the names and addresses of the Client and Approved Inspector should be inserted. A brief description of the work to be done and the address of the Project should also be inserted. On pages 4 and 5, Part 1: Contract Details and Fees should be completed carefully; it is also important that where there are alternatives, the appropriate deletions are made. See notes 3 to 12 below. On pages 6 and 7, Part 2: Services should be marked up carefully to show what the Approved Inspector has agreed to do. See note 13 below. On page 3, the Approved Inspector and the Client should sign the contract and print their names, and the date of the latest signature should be inserted on page 2. It is usual for each party to keep a copy of the contract signed by the other. (Note that when a contract has been concluded, the parties and their advisers are permitted to photocopy the signed contract for their use. Otherwise it is a breach of copyright to photocopy the contract or reproduce or transmit it in any way without the publishers permission.) Notes on the Terms and Conditions 3. Domestic client : in clause 1 2 'is' or 'is not' should be deleted to indicate whether the Client is a domestic client or not. A domestic client is one or more individuals who are owners or occupiers of a dwelling. In some instances the law relating to approved inspectors is different depending upon whether the Client is a domestic client or not, and some provisions of the contract in Part 3: Conditions do not apply in the case of a domestic client (indicated in the sidenotes). 4. Project period: in clause 1 3 insert how long it is anticipated that the Project will take, up until the time when the Client can take possession of the site (practical completion). 5. Limitations of liability: clauses 1 5 and It is recommended that the parties agree a suitable total (ie overall or aggregate) amount of damages for which the Approved Inspector might become liable to the Client. See the CIC Liability Briefing Managing liability through financial caps available at The agreed amount should be inserted in clause In agreeing the amount the parties should have regard to (amongst other things) the following: the level of professional indemnity insurance the Approved Inspector has agreed to maintain; the fact that the cap will apply to all claims, for breach of contract or for breach of a duty to take care (that is, in tort ) or for breach of statutory duty or otherwise; the nature and scope of the Services provided by the Approved Inspector; the nature, size and complexity of the Project; and the Fee. 7. In clause , the contract also includes what is called a net contribution clause, which provides that if both the Approved Inspector and another party are liable to the Client in respect of the same loss or damage, the Approved Inspector will only have to pay a fair and reasonable proportion of the Client s losses, having regard to the extent of the Approved Inspector s responsibility for the loss or damage. For a fuller explanation of such clauses, see the CIC Liability Briefing Net contribution clauses available at 8. In clause , the contract provides that if the Approved Inspector is a firm, company or limited liability partnership (LLP), the Client will only hold that firm, company or LLP responsible for the work done, not any individual (employee, director or member) who works for the firm, company or LLP. See the CIC Liability Briefing Personal liability of employees available at 9. Novation: clause 1 6. The provisions for novation will only apply where the Client wishes to transfer the appointment of the Approved Inspector by way of novation to the contractor (for example if a design and build procurement route is used). 10. The Fee: in clause 1 7 indicate whether the Fee is to be a lump sum or charged on a time basis. If a lump sum fee is agreed, the appropriate details should be inserted. Time charge rates should be inserted in all cases, since if any Additional Work is undertaken, it is charged on a time basis (see clause 3 6). 11. Expenses and disbursements: clause 1 8. Note that there are three alternatives (that expenses and disbursements are included within the fee; that they may be charged in addition to the fee; or that certain specified items may be charged). The unused alternatives must be deleted. 12. Instalment payments: clause 1 9 must also be completed. 13. The Services (Part 2): Whether the Approved Inspector is to undertake the Statutory Functions only or a fuller service should be indicated by deleting the text as appropriate. In summary, the Statutory Functions comprise serving the initial notice, undertaking an assessment of plans, consulting as appropriate, inspecting the site and issuing a final certificate(s). If the Approved Inspector is to undertake any additional services within the Fee, this should be clearly indicated by ticking the appropriate boxes and/or adding details in the space provided. If the Approved Inspector is to take on any responsibility for the design or construction of a dwelling (see clause clause 3 3.1), the extent of these responsibilities should be added. Other services requested after the contract has been entered into will be charged on a time basis under clause Insurance: clause 3 7 provides that the Approved Inspector will maintain professional indemnity insurance and public liability insurance in compliance with guidelines for schemes of insurance for Approved Inspectors pursuant to section 47(6) of the Building Act 1984, issued by the Department for Communities and Local Government (or any successor Department responsible for the Building Act 1984). 14 Construction Industry Council 2013
18 Construction Industry Council 26 Store Street London WC1E 7BT tel fax ISBN