Source: http://www.legislation.gov.uk/ukpga/2008/18/schedule/3/enacted
Timestamp: 2019-01-20 20:42:22
Document Index: 783750298

Matched Legal Cases: ['art 1', 'art 2', 'art 2', 'art 1', 'art 3', 'art 3', 'art 3', 'art 3']

SCHEDULE 3Highways
1(1)The nominated undertaker may, in connection with the construction of the works authorised by this Act, stop up each of the highways or parts of highways specified in the following table.
(2)No highway or part of a highway specified in columns (1) and (2) of Part 1 of the following table shall be stopped up under this paragraph unless all the land which abuts on it falls within one or more of the following categories, namely—
(a)land to which there is no right of access directly from the highway or part to be stopped up,
(b)land to which there is reasonably convenient access otherwise than directly from the highway or part to be stopped up,
(c)land the owners and occupiers of which have agreed to the stopping up of the highway or part, and
(d)land which is in the possession of the Secretary of State.
(3)No highway or part of a highway specified in columns (1) and (2) of Part 2 of the following table shall be stopped up under this paragraph if a new highway is specified in relation to it in column (3) of that Part of the table, by reference to the letters and numbers shown on the deposited plans or by reference to scheduled works, until—
(a)where the new highway is provided in exercise of the powers conferred by this Act, the later of the date of practical completion and the date on which it is first open for public use, and
(b)where it is not, the date on which it is first open for public use.
(4)Where a new highway specified in column (3) of Part 2 of the following table is provided in exercise of the powers conferred by this Act, the date of practical completion of the highway, or the date on which it is first open for public use, shall be taken for the purposes of sub-paragraph (3) to be what it is taken to be for the purposes of paragraph 11(2).
Footpath within Westbourne Green Sports Complex between points P5, P6 and P7
North-eastern side of Eastbourne Terrace within extent of narrowing shown on the deposited plans
Falconberg Court
London Borough of Camden Andrew Borde Street
London Borough of Islington Cowcross Street between points P1 and P2
Hayne Street between points P3 and P4
Fore Street Avenue between points P1 and P2
Moorfields between points P2 and P3
Fulbourne Street between points P1 and P2
Court Street between points P3 and P4
Wood’s Buildings between points P5 and P6
South-eastern side of Durward Street within the extent of narrowing shown on the deposited plans between points P2 and P7
Garden Street between points P5 and P6
Eleanor Street between points P1 and P2
Bostall Manorway between points P3 and P4
Abbey Terrace between points P5 and P6
London Borough of Havering Footpath (FP 123) between Beechfield Gardens and Nursery Walk
>City of Westminster Westbourne Park Passage within the limits of deviation of Work No. 1/9C Work No. 1/9C
Westbourne Park Passage within the limits of deviation of Work No. 1/9D Work No. 1/9D
London Borough of Tower Hamlets Footpath between Stepney Way and Stepney Green between points P1, P2 and P3 and between points P2 and P4 New footpath between points P1, P4, P5 and P6
London Borough of Newham Footpaths between the Excel Centre and Victoria Dock Road between points P1, P2, P3, P4, P5, P6, P7, P8 and P9 and between points P6 and P11 New footpath through intended station, part of Work No. 1/5 between points P10 and P11
Footpath between Albert Road and Factory Road between points P1 and P2 Work No. 1/32D
Barbers Road between points P1 and P2 Works Nos. 2/6A, 2/6B and 2/7
Pudding Mill Lane between points P3 and P4 Works Nos. 2/6A, 2/6B and 2/7
Marshgate Lane within the relevant limits Works Nos. 2/6A and 2/6B
Footpath (Greenway) between points P6, P7, P8, P9, P10, P11, P12 and P13 and between points P9 and P11 New footpath between points P5, P14 and P13
London Borough of Greenwich Footpath on eastern side of Church Manor Way between points P1 and P2 Work No. 1/34
Footpath between Mottisfont Road and Bostall Manor Way between points P1 and P2 Work No. 1/36
London Boroughs of Greenwich and Bexley Footpaths over Abbey Wood Station between points P7, P8, P9, P10 and P11 and between points P11 and P12 New footpath through intended station, part of Work No. 1/7
Felixstowe Road within the relevant limits Work No. 1/37B
London Borough of Bexley Gayton Road Work No. 1/37C
London Borough of Barking & Dagenham Footpath on eastern side of Whalebone Lane South between points P1 and P3 New footpath between points P1, P2 and P3
London Borough of Havering Footpath adjacent to bus stand, Atlanta Boulevard Work No. 2/15D
County of Berkshire, Borough of Slough Hollow Hill Lane between points P1 and P2 Work No. 3/9D
County of Buckinghamshire, District of South Bucks, Parish of Iver Thorney Lane South between points P1 and P2 Works Nos. 3/9B and 3/9C
London Borough of Hillingdon Footpath and cycleway (Kingston Lane) between points P1 and P2 Work No. 3/10F
Old Stockley Road between points P1 and P2 Footpath and cycleway between points P1 and P2 (Work No. 3/14)
3(1)On a highway or part of a highway being stopped up under paragraph 1 or 2—
(a)all rights of way over or along it shall be extinguished, and
(b)the Secretary of State may appropriate and use, without making any payment, so much of the site of it as is bounded on both sides by land which he owns.
(2)The nominated undertaker shall compensate any person who suffers loss by the extinguishment under this paragraph of a private right of way.
(3)Any dispute as to a person’s entitlement to compensation under sub-paragraph (2), or as to the amount of such compensation, shall be determined under and in accordance with Part 1 of the Land Compensation Act 1961 (c. 33).
(4)The Secretary of State shall not be entitled to any mines or minerals under land which he is entitled to appropriate and use under sub-paragraph (1)(b), with the exception of minerals necessarily extracted or used in the construction of the undertaking which the nominated undertaker is authorised to carry on by this Act.
(5)Part 3 of Schedule 2 to the Acquisition of Land Act 1981 (c. 67) (regulation of the working of mines or minerals underlying an authorised undertaking) shall apply in relation to the working of any mines or minerals underlying land which the Secretary of State is entitled to appropriate and use under sub-paragraph (1)(b) with the following modifications—
(a)references to the undertaking shall be construed as references to the undertaking which the nominated undertaker is authorised to carry on by this Act,
(b)in paragraphs 3 to 5 and 7 to 9, references to the acquiring authority shall be construed as references to the nominated undertaker, and
(c)in paragraph 6, the first of the references to the acquiring authority shall be construed as a reference to the nominated undertaker.
Permanent obstruction
4(1)The powers conferred by paragraph 1 or 4 of Schedule 2 may be exercised in such a way as to obstruct the highway, but only with the consent of the highway authority, such consent not to be unreasonably withheld.
(2)Any dispute with a highway authority under sub-paragraph (1) shall, if the parties agree, be referred to arbitration, but shall otherwise be determined by the Secretary of State.
(3)If a highway authority which receives an application for consent under sub-paragraph (1) fails to notify the applicant of its decision on the application before the end of the period of 28 days beginning with the date on which the application was made, it shall be deemed to have granted it.
Temporary interference
5(1)For the purposes of the works authorised by this Act, the nominated undertaker may—
(a)temporarily stop up or alter or divert any highway or part of a highway,
(b)for any reasonable time divert traffic from, and prevent persons passing along, any highway or part of a highway, and
(c)break up or interfere with any highway or part of a highway (including any sewer, drain or tunnel in it).
(2)The nominated undertaker shall provide reasonable access for pedestrians going to or from premises abutting on a highway affected by the exercise of the powers conferred by sub-paragraph (1) if there would otherwise be no such access.
(3)Before exercising the powers conferred by sub-paragraph (1) in relation to a highway and to an extent specified in the following table, the nominated undertaker shall consult the highway authority about the exercise of the powers.
City of Westminster Westbourne Park Passage Between points T1 and T2
Harrow Road Between points T1 and T2
Westbourne Park Villas Between points T3 and T4
Bishop’s Bridge Road Within the relevant limits
Eastbourne Terrace Entire length
Cleveland Terrace Within the relevant limits
Chilworth Street Within the relevant limits
South Wharf Road Within the relevant limits
Praed Street Within the relevant limits
Craven Road Within the relevant limits
Westbourne Terrace Within the relevant limits
Chilworth Mews Entire length
Eastbourne Mews Entire length
Spring Street Between points T1 and T2
Bayswater Road Between points T1 and T2
Park Lane Between points T4 and T5 on Sheet No. 8 of the deposited Plans and points T5 and T6 on Sheet No. 42 of the deposited Plans
Pedestrian subway between western and eastern sides of Park Lane Between points T1, T2 and T3
Weighhouse Street Between points T1 and T2
Gilbert Street Between points T1 and T3
St. Anselm’s Place Entire length
Davies Street Within the relevant limits
South Molton Lane Between points T4 and T5
Stratford Place Within the relevant limits
Marylebone Lane Within the relevant limits
Dering Street Within the relevant limits
New Bond Street Within the relevant limits
Brook Street Within the relevant limits
Tenterden Street Entire length
Hanover Square Entire length
Princes Street Within the relevant limits
St George Street Within the relevant limits
Wardour Street Between points T5 and T6
Hollen Street Within the relevant limits
Sheraton Street Within the relevant limits
Oxford Street Within the relevant limits
Newman Street Within the relevant limits
Great Chapel Street Entire length
Diadem Court Entire length
Fareham Street Entire length
Dean Street Within the relevant limits
Soho Square Between points T1 and T2
Carlisle Street Entire length
Falconberg Mews Entire length
Sutton Row Entire length
Greek Street Within the relevant limits
Manette Street Entire length
Goslett Yard Entire length
City of Westminster and London Borough of Camden Tottenham Court Road Within the relevant limits
Charing Cross Road Within the relevant limits
St Giles Circus Entire length
London Borough of Camden New Oxford Street Within the relevant limits
Earnshaw Street Entire length
Denmark Street Entire length
Denmark Place Between points T5 and T6
St Giles High Street Between points T3 and T4
Fisher Street Entire length
Southampton Row Between points T1 and T2
Catton Street Entire length
Red Lion Square Between points T3 and T4
Drake Street Between points T5 and T3
London Boroughs of Camden and Islington Farringdon Road Within the relevant limits
City of London Farringdon Street Within the relevant limits
West Smithfield Within the relevant limits
Snow Hill Within the relevant limits
Long Lane Within the relevant limits
Lindsey Street Entire length
Hayne Street Between points T3 and P4
Aldersgate Street Within the relevant limits
Eldon Street Entire length
London Wall Within the relevant limits
Fore Street Avenue Between points T1 and T2
Silk Street Within the relevant limits
Moor Lane Between points T3 and T4
Moorfields Entire length
Moor Place Entire length
Keats Place Entire length
Moorgate Within the relevant limits
Finsbury Circus Within the relevant limits
Circus Place Entire length
Blomfield Street Entire length
Broad Street Avenue Entire length
Liverpool Street Entire length
Old Broad Street Within the relevant limits
Wormwood Street Entire length
Bishopsgate Within the relevant limits
Camomile Street Within the relevant limits
Grand Avenue Within the relevant limits
Eldon Street Within the relevant limits
London Boroughs of Islington and Camden and City of London Charterhouse Street Within the relevant limits
London Borough of Islington and City of London Charterhouse Square Entire length
Carthusian Street Entire length
Ropemaker Street Within the relevant limits
South Place Entire length
London Borough of Islington St John Street Within the relevant limits
Finsbury Pavement Within the relevant limits
Finsbury Street Within the relevant limits
Fox & Knot Street Entire length
Turnmill Street Within the relevant limits
Cowcross Street Between points P2 and T1
London Borough of Tower Hamlets Princelet Street Between points T1 and T2
Hanbury Street Between points T3 and T4
Vallance Road Between points T3 and T4 and points T5 and T6
Whitechapel Road Within the relevant limits
Spelman Street Within the relevant limits
Durward Street So much as is not permanently stopped up within the extent of narrowing shown on the deposited plans
Court Street Between points T9 and P3
Castlemaine Street Between points T7 and T8
Fulbourne Street Between points P1 and T10
Winthrop Street Entire length
Brady Street Within the relevant limits
Stepney Green Between points T1 and T2 and within the relevant limits
Garden Street T3 and P5
White Horse Lane Within the relevant limits
Stepney High Street Within the relevant limits
Stepney Way Within the relevant limits
Commercial Road Between points T1 and T2
Mile End Road Within the relevant limits
Footpath between Cheshire Street and Fleet Street Hill Between points T1 and T2
Tapp Street Between points T5 and T6
Collingwood Street Between points T7 and T8
Hemming Street Between points T9 and T10
Cudworth Street Between points T6, T8 and T2
Coventry Road Between points T1 and T2
Buckhurst Street Between points T3 and T4
Cambridge Heath Road Within the relevant limits
Braintree Street Within the relevant limits
Mantus Road Between points T5 and T6
Globe Road Between points T7 and T8
Bancroft Road Between points T9 and T10
Morpeth Street Within the relevant limits
Longnor Road Between points T1 and T2
Grove Road Within the relevant limits
Burdett Road Within the relevant limits
Eleanor Street Within the relevant limits
Rounton Road Between points T3 and T4
Wick Lane Within the relevant limits
Wrexham Road Between points T9 and T10
Blackwall Tunnel Northern Approach Road Between points T3 and T4, points T5 and T6, points T7 and T8 and points T11 and T12
Bow Road Between points T12 and T13
Payne Road Between points T11 and T13
West India Dock Road Between points T1 and T2
London Borough of Newham Lower Lea Crossing Between points T1 and T2
Victoria Dock Road Between points T1, T2 and T3
Freemasons Road Within the relevant limits
North Woolwich Road Within the relevant limits
Footpath FP 108 between Festoon Way and Connaught Bridge Between points T1 and T2 and points T3 and T4
Footpath between Connaught Road and Factory Road Within the relevant limits
Connaught Bridge Within the relevant limits
Connaught Road Within the relevant limits
Albert Road Within the relevant limits
Factory Road Within the relevant limits
Store Road Entire length
Pier Road Within the relevant limits
Bankside footpath on the eastern side of the River Lea Within the relevant limits
Barbers Road / Cook’s Road Between points T3 and P1
Pudding Mill Lane Between points T4 and P3 and points P4 and T5
Footpath (Greenway) adjacent to Marshgate Lane on northern side of the railway Between points T6 and T7 and points T6 and T8
Footpath adjacent to City Mill River Between points T9 and T11
Footpath (Greenway) on eastern side of City Mill River Between points T12 and T13 and points P13, T10 and T13
Marshgate Lane Between points T1 and T2
Manor Park Road Between points T1 and T2
Lugg Approach Within the relevant limits
Goodmayes Road Within the relevant limits
London Borough of Greenwich Warren Lane Within the relevant limits
Beresford Street Within the relevant limits
Plumstead Road Within the relevant limits
Gunning Street Within the relevant limits
Reidhaven Road Within the relevant limits
White Hart Road Within the relevant limits
Marmadon Road Within the relevant limits
Church Manor Way Within the relevant limits
Mottisfont Road Within the relevant limits
Bostall Manorway Within the relevant limits
London Boroughs of Greenwich and Bexley Felixstowe Road Within the relevant limits
Harrow Manorway Within the relevant limits
London Borough of Bexley Wilton Road Within the relevant limits
Florence Road Within the relevant limits
Fendyke Road Within the relevant limits
Alsike Road Within the relevant limits
Footpath FP 3 adjacent to River Thames at Manor Wharf, Belvedere Between points T1, T2 and T3 and points T4 and T2
Footpath FP 4 between Norman Road and the footpath FP 3 adjacent to River Thames at Manor Wharf, Belvedere Between points T4 and T5 and points T6 and T7
London Borough of Redbridge Goodmayes Road Within the relevant limits
London Borough of Barking & Dagenham Valence Avenue Within the relevant limits
Saville Road Within the relevant limits
London Boroughs of Barking & Dagenham and Havering Crow Lane Within the relevant limits
London Borough of Havering Nursery Walk and FP 127 Within the relevant limits
London Road Within the relevant limits
Jutsums Lane Within the relevant limits
Footpath FP 123 within Jutsums Recreational Ground Within the relevant limits
Cambridge Avenue Between points T1 and T2
Oldchurch Road Within the relevant limits
Waterloo Road Within the relevant limits
Exchange Street Within the relevant limits
Havanna Close Within the relevant limits
Eastern Road Within the relevant limits
Atlanta Boulevard Within the relevant limits
Footpath FP 128 between Exchange Street and The Battis Between points T1 and T2
South Street Within the relevant limits
Crossways Within the relevant limits
Upper Brentwood Road Within the relevant limits
Southend Arterial Road Footway Within the relevant limits
Station Road Within the relevant limits
County of Essex, Borough of Brentwood Hunter Avenue Within the relevant limits
Alexander Lane Within the relevant limits
County of Essex, District of Basildon Footpath FP 136 between the Meads and Terminus Drive Within the relevant limits
County of Berkshire, Royal Borough of Windsor & Maidenhead Silco Drive Within the relevant limits
Shoppenhanger’s Road Between points T1 and T2
Station Approach Within the relevant limits
County of Berkshire, Borough of Slough Burnham Lane Within the relevant limits
Dover Road Within the relevant limits
Leigh Road Between points T1 and T2
Farnham Road (A355) Between points T1 and T2
Stoke Poges Lane Within the relevant limits
Footpath and steps within Salt Hill Pleasure Grounds Within the relevant limits
William Street Within the relevant limits
Wexham Road Within the relevant limits
Uxbridge Road Within the relevant limits
Middlegreen Road Between points T1 and T2
St. Mary’s Road Within the relevant limits
Trenches Bridge footpath (FP 47a) and cycleway Within the relevant limits
Hollow Hill Lane Within the relevant limits
Market Lane Within the relevant limits
County of Buckinghamshire, District of South Bucks, Parish of Iver Bathurst Walk Within the relevant limits
Footpath FP 16 between Colne Valley Way and Court Lane Within the relevant limits
London Borough of Hillingdon Weirside Gardens Within the relevant limits
Horton Bridge Road Between points T1 and PI
Kingston Lane Between points T2 and P2
Stockley Road Between points T1 and T2
Station Road, Hayes Within the relevant limits
Subway between Blyth Road and Station Approach Between points T1 and T2
Station Approach Entire length
Keith Road Within the relevant limits
Nestle’s Avenue Within the relevant limits
London Borough of Ealing Footpath FP 112 between Park Avenue and Merrick Road Within the relevant limits
Golden Manor Within the relevant limits
Alwyne Road Within the relevant limits
Manor Road Within the relevant limits
Haven Green Within the relevant limits
The Mall Within the relevant limits
Noel Road Within the relevant limits
Twyford Avenue Within the relevant limits
Oakley Avenue Within the relevant limits
Horn Lane Within the relevant limits
(4)The purpose of consultation under sub-paragraph (3) shall be to ensure public safety and, so far as reasonably practicable, to reduce public inconvenience.
(5)Before exercising the powers conferred by sub-paragraph (1) in relation to a highway, or to an extent, not specified in the table in sub-paragraph (3), the nominated undertaker shall obtain the consent in writing of the highway authority.
(6)Consent under sub-paragraph (5) shall not be unreasonably withheld, but may be given subject to such conditions as the highway authority may reasonably require in the interest of public safety or convenience.
(7)If a highway authority which receives an application for consent under sub-paragraph (5) fails to notify the applicant of its decision on the application before the end of the period of 28 days beginning with the date on which the application was made, it shall be deemed to have granted the application.
(8)Sub-paragraph (7) shall have effect in relation to an application for consent which relates to a GLA side road (within the meaning of the Road Traffic Regulation Act 1984 (c. 27)) or a road which is designated under section 60(1) or 61(1) of the Traffic Management Act 2004 (c. 18) (roads in Greater London which are strategic roads) with the substitution for “28” of “42”.
(9)Any dispute with a highway authority about consent under sub-paragraph (5) shall, if the parties agree, be referred to arbitration, but shall otherwise be determined by the Secretary of State.
(10)It is hereby declared for the avoidance of doubt that there is no need to reinstate a highway or part of a highway in relation to which any of the powers conferred by sub-paragraph (1) has been exercised where the exercise of the power comes to an end on the exercise, in relation to the highway or part, of the power conferred by paragraph 1(1) or 2(1).
Working sites in highways
6Any highway or part of a highway which is stopped up under paragraph 5(1)(a) may be used as a working site if it is within the limits of deviation for the scheduled works or within the limits of land to be acquired or used.
7(1)The nominated undertaker may, for the purposes of the works authorised by this Act, enter upon any highway within the limits of deviation for the scheduled works or within the limits of land to be acquired or used and—
(a)place, maintain or alter, or change the position of, apparatus in it,
(b)remove apparatus from it, and
(c)execute any works required for, or incidental to, any works authorised by paragraph (a) or (b).
(2)In this paragraph, “apparatus” has the same meaning as in Part 3 of the New Roads and Street Works Act 1991 (c. 22).
9(1)Where under this Act the nominated undertaker—
(a)constructs a new highway, or
(b)alters a highway, otherwise than by carrying out street works within the meaning of Part 3 of the New Roads and Street Works Act 1991,
the construction or alteration shall be completed to the reasonable satisfaction of the highway authority.
(2)Where work to which sub-paragraph (1) applies has been completed to the reasonable satisfaction of a highway authority, it shall certify that fact in writing to the nominated undertaker.
(3)If the nominated undertaker requests a highway authority to issue a certificate under sub-paragraph (2) and the highway authority does not before the end of the period of 28 days beginning with the date on which the request was made—
(a)issue a certificate under that sub-paragraph, or
(b)notify the nominated undertaker of its decision to refuse to issue such a certificate,
it shall be deemed to have issued such a certificate at the end of that period.
(4)Any dispute with a highway authority under this paragraph shall, if the parties agree, be referred to arbitration, but shall otherwise be determined by the Secretary of State.
10(1)Sub-paragraph (2) applies where under this Act the nominated undertaker—
(a)realigns a highway which is constituted by or comprises a carriageway, or
(b)constructs a new highway which is constituted by or comprises a carriageway.
(2)The realignment, or construction, shall be carried out in accordance with plans, sections and specifications approved by the highway authority at the request of the nominated undertaker, such approval not to be unreasonably withheld.
(3)Any dispute with a highway authority under sub-paragraph (2) shall, if the parties agree, be referred to arbitration, but shall otherwise be determined by the Secretary of State.
(4)If, on application by the nominated undertaker for the approval of plans, sections or specifications under sub-paragraph (2), the highway authority fails to notify the nominated undertaker of its decision on the application before the end of the period of 28 days beginning with the date on which the application was made, it shall be deemed to have approved the plans, sections or specifications as submitted.
11(1)Sub-paragraph (2) applies where under this Act the nominated undertaker—
(b)alters a highway, otherwise than by carrying out street works within the meaning of Part 3 of the New Roads and Street Works Act 1991 (c. 22).
(2)Unless otherwise agreed between the nominated undertaker and the highway authority, the new or altered highway shall be maintained by and at the expense of the nominated undertaker for a period of 12 months from the later of—
(a)the date of practical completion, and
(b)the date on which it is first open for public use;
and after the end of that period shall be maintained by and at the expense of the highway authority.
(3)Where in relation to a highway to which sub-paragraph (2) applies the highway authority is satisfied that the highway is practically complete or is open for public use, it shall, at the request of the nominated undertaker, certify to it in writing the date of practical completion of the highway or, as the case may be, the date on which it was first open for public use.
(4)If the highway authority refuses a request to issue a certificate under sub-paragraph (3), or if the nominated undertaker disputes the date given in a certificate under that sub-paragraph, the matter shall, if the parties agree, be referred to arbitration, but shall otherwise be determined by the Secretary of State.
(5)For the purposes of sub-paragraph (2), the date of practical completion of a highway, or the date on which it is first open for public use, shall be taken to be—
(a)where the date has been determined under sub-paragraph (4), the date so determined, and
(b)where it has not, the date certified under sub-paragraph (3).
(6)Sub-paragraph (2) shall not have effect to impose any obligation in relation to—
(a)the structure of any bridge carrying a highway over any railway of the nominated undertaker, or
(b)the structure of any tunnel carrying a highway under any such railway.
(7)Nothing in this paragraph shall prejudice the operation of section 87 of the New Roads and Street Works Act 1991 (c. 22).
12Notwithstanding anything in section 46 of the Railways Clauses Consolidation Act 1845 (c. 20), as incorporated with this Act, the nominated undertaker shall not be liable to maintain the surface of any highway under or over which the scheduled works shall be constructed, or the immediate approaches to any such highway.
Agreements with highway authorities etc.
14(1)Where under this Schedule the nominated undertaker is authorised to stop up or interfere with an existing highway or part of an existing highway, it may enter into agreements with the persons having the charge, management or control of the highway concerning the construction (or contribution towards the expenses of construction) of—
(a)any new highway to be provided in substitution,
(b)any alteration of the existing highway, and
(c)any other related matters.
(2)The nominated undertaker may, by agreement with any such persons, delegate to them the power of constructing any such new highway or any such alteration of an existing highway, including any bridge over any railway, and, where the nominated undertaker is responsible for maintaining the new or altered highway (or bridge), the power to maintain it.
15(1)The nominated undertaker may enter upon, take and use for the purposes of the works authorised by this Act so much of the subsoil of any highway within the limits of deviation for the scheduled works or within the limits of land to be acquired or used as shall be required for the purpose of the construction or maintenance of those works, without being required to acquire that subsoil or any interest in it.
(2)The power conferred by sub-paragraph (1) shall not be exercisable in relation to the subsoil of a highway within the limits of land to be acquired or used, but outside the limits of deviation for the scheduled works, if the highway is comprised in land specified in the following table.
City of Westminster 30d, 38, 81, 85, 112, 115, 117, 120, 121, 213, 218, 340, 341, 416, 417, 419, 420, 423, 447, 448, 449, 453, 454, 455, 548, 549, 549a, 551, 566, 595, 598, 600, 666, 684, 685, 689, 690 and 691
London Borough of Camden 1, 3, 5, 7, 10, 11, 13, 30, 31, 32, 153, 154, 155, 279, 281, 282 and 283
London Borough of Islington 1, 3, 4, 13, 24, 25, 34, 90, 92, 93, 94, 95 and 99
City of London 1, 2, 3, 4, 7, 8, 9, 17, 18, 20, 34, 36, 52, 53, 55a, 71, 72, 73, 74, 80a, 81, 101, 102, 103, 108, 113, 115, 125, 136, 138, 143, 159, 160 and 161
London Borough of Tower Hamlets 224, 224a, 225, 225b, 227a, 250, 252, 252a, 252b, 269, 280, 281, 290, 293, 294, 391, 393, 396, 398, 664, 820, 988, 990, 991, 993, 1135, 1145, 1247c, 1295, 1412a, 1413a, 1421, 1421b, 1423a, 1445 and 1446
London Borough of Newham 8, 76, 155, 164, 189, 193, 205, 206, 258, 259, 260, 278, 288, 366, 379, 565, 619 and 670
London Borough of Greenwich 3, 5, 15, 31e, 35a, 100, 101, 104, 109, 125, 125a, 130, 138, 144, 155, 159, 164, 169, 173, 182, 187 and 227
London Borough of Bexley 28, 64 and 68
London Borough of Redbridge 26 and 41
London Borough of Barking & Dagenham 17 and 18
London Borough of Havering 2, 11, 12, 24, 105, 117, 120, 134, 138, 140, 149, 154, 164 and 194
Borough of Brentwood 24 and 52
District of Basildon 13 and 14
Borough of Slough 14, 20, 22, 23, 32, 53, 56, 60, 113, 162, 168 and 253a
London Borough of Hillingdon 97, 98, 115, 116 and 211b
London Borough of Ealing 9, 62, 62a, 88, 125, 144, 159, 160, 164, 177, 183 and 186
(3)In the case of a highway comprised in land specified in the table in columns (1) and (2) of the table in paragraph 10 of Schedule 6, the power conferred by sub-paragraph (1) shall only be exercisable in relation to so much of the subsoil of the highway as falls within the description specified in relation to the land in column (3) of the table.
(4)In the case of a highway comprised in land specified in the table in paragraph 11(1) of Schedule 6, the power conferred by sub-paragraph (1) shall only be exercisable in relation to so much of the subsoil of the highway as lies more than 9 metres beneath the level of the surface of the highway.
(5)For the avoidance of doubt, it is hereby declared that the restrictions imposed by sub-paragraphs (2), (3) and (4) on the power conferred by sub-paragraph (1) do not affect the power conferred by paragraph 7(1).