Source: https://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title28-section1499&num=0&edition=prelim
Timestamp: 2020-07-11 18:07:57
Document Index: 640402156

Matched Legal Cases: ['§ 1499', '§202', '§133', '§325', '§902', '§3', '§4', '§1', '§202']

[USC02] 28 USC 1499: Liquidated damages withheld from contractors under chapter 37 of title 40
<< Previous TITLE 28 / PART IV / CHAPTER 91 / § 1499 Next >>
28 USC 1499: Liquidated damages withheld from contractors under chapter 37 of title 40 Text contains those laws in effect on July 10, 2020
(June 25, 1948, ch. 646, 62 Stat. 942 ; Pub. L. 87–581, title II, §202(a), Aug. 13, 1962, 76 Stat. 360 ; Pub. L. 97–164, title I, §133(e)(1), (2)(A), Apr. 2, 1982, 96 Stat. 40 , 41; Pub. L. 101–650, title III, §325(b)(7), Dec. 1, 1990, 104 Stat. 5121 ; Pub. L. 102–572, title IX, §902(a)(1), Oct. 29, 1992, 106 Stat. 4516 ; Pub. L. 107–217, §3(g)(3), Aug. 21, 2002, 116 Stat. 1299 ; Pub. L. 109–284, §4(2), Sept. 27, 2006, 120 Stat. 1211 .)
Based on section 324 of title 40, U.S.C., 1940 ed., Public Buildings, Property and Works (June 19, 1912, ch. 174, §1, 37 Stat. 137 ).
2006-Pub. L. 109–284 substituted "chapter 37 of title 40" for "Contract Work Hours and Safety Standards Act" in section catchline.
2002-Pub. L. 107–217 substituted "section 3703 of title 40" for "section 104 of the Contract Work Hours and Safety Standards Act".
1990-Pub. L. 101–650 substituted "Hours and Safety Standards" for "Hours Standards" in text.
1982-Pub. L. 97–164 substituted "Contract Work Hours and Safety Standards Act" for "Contract Work Hours Standards Act" in section catchline and "United States Claims Court" for "Court of Claims" in text.
1962-Pub. L. 87–581 amended section generally, substituting "Liquidated damages withheld from contractors under Contract Work Hours Standards Act" for "Penalties imposed against contractors under eight hour law" in section catchline, and "liquidated damages withheld from a contractor or subcontractor under section 104 of the Contract Work Hours Standards Act" for "a penalty withheld from a contractor or subcontractor under section 324 of Title 40" in text.
Amendment by Pub. L. 87–581 effective 60 days after Aug. 13, 1962, but shall not affect contracts existing or thereafter entered into pursuant to invitations for bids outstanding on Aug. 13, 1962, see section 204 of Pub. L. 87–581, Aug. 13, 1962, 76 Stat. 360 .
Pub. L. 87–581, title II, §202(b), Aug. 13, 1962, 76 Stat. 360 , provided that the Court of Claims (now United States Court of Federal Claims) was to continue to have jurisdiction to render judgment upon certain claims for a penalty withheld from a contractor or subcontractor under section 324 of former Title 40, Public Buildings, Property, and Works, in connection with any contract subject to that section existing on the date sixty days after Aug. 13, 1962, or thereafter entered into pursuant to invitations for bids that were outstanding on Aug. 13, 1962.