Source: http://www.dot.state.oh.us/Divisions/ContractAdmin/Claims/Claims-HTMs/district-main.htm
Timestamp: 2014-12-20 01:36:33
Document Index: 90063597

Matched Legal Cases: ['ART 1', 'ART 2', 'ART 1', 'ART 2', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'art 1', 'ART 2']

Construction Management - Claims Information District 2 MILLER BROS CONST INC Year: 2003 Project Number: 990141 PID Number: 9159 Specification Year: 1997 Dispute/Claim Number: 02-0141(99)-02 Dispute Resolution Forum: Deputy Director's Board Location: LUC - S.R. 2 - 21.24 PART 1; S.R. 2 - 27.26 (JERUSALEM ROAD) PART 2 (City of Oregon) Description: Asphalt Pavement Rutting Issues: Asphalt pavement rutting Decision/Recommendation: 02-0141(99)-02
District 2 POSEN CONSTRUCTION INC Year: 2010 Project Number: 098019 PID Number: 25555 Specification Year: 2008 Dispute/Claim Number: 02-098019-01 Dispute Resolution Forum: Director's Claim Board Location: WOO - IR/LUC-75-32.68/0.00 Description: Extra Hydro-demolition work due to thicker overlay on deck than shown on plans Issues: Differing site conditions, Inefficiency/Loss of productivity, Entitlement agreed/damages in dispute Decision/Recommendation: 02-098019-01
District 2 MILLER BROS CONST INC Year: 2002 Project Number: 990141 PID Number: 9159 Specification Year: 1997 Dispute/Claim Number: 02-0141(99)-0901-01 Dispute Resolution Forum: Deputy Director's Board Location: LUC - S.R. 2 - 21.24 PART 1; S.R. 2 - 27.26 (JERUSALEM ROAD) PART 2 (City of Oregon) Description: Brick Salvage Value, Various Additional Costs Decision/Recommendation: 02-0141(99)-0901-01
District 2 FRU-CON CONSTRUCTION CORPORATION Year: 2004 Project Number: 010493 PID Number: 20208 Specification Year: 1997 Dispute/Claim Number: D2.025 Dispute Resolution Forum: Dispute Review Board Location: LUC - IR 280 - 2.96 Description: Discrepancy in Concrete Quantity for Precast Segmental Concrete Issues: Discrepancy in quantity, Signif. change in scope/character of work, Notice Decision/Recommendation: D2.025
District 2 GREAT LAKES CONSTRUCTION CO Year: 2007 Project Number: 040584 PID Number: 23956 Specification Year: 2002 Dispute/Claim Number: 02-040584-01 and -02 Dispute Resolution Forum: Director's Claim Board Location: OTT - SR 2-28.47/0.00 Description: contractor used dry construction method to place concrete in drilled shaft even though wet method should have been used. ODOT required contractor to remove and replace drilled shaft or prove it met strenght requirements. Contractor replaced and requests compensation for extra work Issues: Drilled shafts, Inspection, Workmanlike construction Decision/Recommendation: 02-040584-01 and -02
District 3 RUHLIN COMPANY Year: 2007 Project Number: 040082 PID Number: 18631 Specification Year: 2002 Dispute/Claim Number: 03-040082-01 Dispute Resolution Forum: Director's Claim Board Location: WAY - USR 30/250-9.18/9.98 (City of Wooster) Description: excavation and embankment - differing site conditions, undercuts, plan errors Issues: Differing site conditions, Equitable Adjustment, Errors and Omissions, Signif. change in scope/character of work Decision/Recommendation: 03-040082-01
District 3 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 050343 PID Number: 14018 Specification Year: 2002 Dispute/Claim Number: 03-050343-01 Dispute Resolution Forum: Director's Claim Board Location: MED - IR 71-9.56 Description: Value Engineering Participation Issues: Value Engineering Proposal, Contract interpretation/ambiguity Decision/Recommendation: 03-050343-01
District 3 COSMOS INDUSTRIAL SERVICES INC Year: 2012 Project Number: 110155 PID Number: 81374 Specification Year: 2010 Dispute/Claim Number: 03-110155-01 Dispute Resolution Forum: Director's Claim Board Location: LOR - VA-BH-FY2011 Description: Maintenance of Traffic Pay Items Issues: Contract interpretation/ambiguity Decision/Recommendation: 03-110155-01
District 3 KOKOSING CONSTRUCTION COMPANY INC Year: 2005 Project Number: 049077 PID Number: 78096 Specification Year: 2002 Dispute/Claim Number: 03-049077-01 Dispute Resolution Forum: Deputy Director's Board Location: MRW - IR 71 - 19.54/0.00 Description: Joint Repairs Issues: Dispute Resolution Process, Type A Emergency, Inspection, Acceptance (express/implied), Workmanlike construction, Responsibility for project, Burden of proof Decision/Recommendation: 03-049077-01
District 3 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 050343 PID Number: 14018 Specification Year: 2002 Dispute/Claim Number: 03-050343-02 Dispute Resolution Forum: Director's Claim Board Location: MED - IR 71-9.56 Description: Delay Costs due to Delay in VE response Issues: CPM Progress Schedule, Change order policy, Delay - owner caused Decision/Recommendation: 03-050343-02
District 3 RUHLIN COMPANY Year: 2007 Project Number: 040082 PID Number: 18631 Specification Year: 2002 Dispute/Claim Number: 03-040082-03 Dispute Resolution Forum: Director's Claim Board Location: WAY - USR 30/250-9.18/9.98 (City of Wooster) Description: Payment of granular embankment Issues: Burden of proof, Discrepancy in quantity Decision/Recommendation: 03-040082-03
District 3 SPECIALIZED CONSTRUCTION INC Year: 2010 Project Number: 080477 PID Number: 80050 Specification Year: 2008 Dispute/Claim Number: 03-080477-01 Dispute Resolution Forum: Director's Claim Board Location: CRA - VA-CHIP-FY2009 Description: Chip Seal Warranty Issues: Warranty, Acceptance (express/implied) Decision/Recommendation: 03-080477-01
District 3 MOSSER CONSTRUCTION INC Year: 2009 Project Number: 060216 PID Number: 23504 Specification Year: 2005 Dispute/Claim Number: 03-060216-01 Dispute Resolution Forum: Arbitration Location: RIC - CR 424-0.62 Description: Removal of Granular Embankment Issues: Acceptance (express/implied), ODOT Testing Procedures Decision/Recommendation: 03-060216-01
District 3 RUHLIN COMPANY Year: 2007 Project Number: 040082 PID Number: 18631 Specification Year: 2002 Dispute/Claim Number: 03-040082-02 Dispute Resolution Forum: Director's Claim Board Location: WAY - USR 30/250-9.18/9.98 (City of Wooster) Description: requesting return of liquidated damages, additional costs for MOT due to Issues: Delay - owner caused, Duty to coordinate subs, Inefficiency/Loss of productivity Decision/Recommendation: 03-040082-02
District 3 BECDIR CONSTRUCTION COMPANY Year: 2012 Project Number: 076004 PID Number: 13136 Specification Year: 2005 Dispute/Claim Number: 03-076004-03 Dispute Resolution Forum: Director's Claim Board Location: ERI - USR 250 - 19.742 (12.43) (Village of Milan) Description: Final Quantities - Pavement Removed, Aggregate Base, Removal of Pavement Markings, Beam Seat Repair Issues: Contract interpretation/ambiguity, Discrepancy in quantity, Method of Measurement Decision/Recommendation: 03-076004-03
District 4 VELOTTA COMPANY Year: 2008 Project Number: 030534 PID Number: 21004 Specification Year: 2002 Dispute/Claim Number: 04-030543-02 Dispute Resolution Forum: Director's Claim Board Location: POR - IR 76 - 9.50 Description: Temporary Pavement Repairs Issues: Contractor proposed change, Workmanlike construction Decision/Recommendation: 04-030543-02
District 4 WOLF CREEK ENGINEERING AND CONTRACTING INC Year: 2008 Project Number: 060440 PID Number: 23705 Specification Year: 2005 Dispute/Claim Number: 04-060440-01 Dispute Resolution Forum: Director's Claim Board Location: SUM - IR 277 - 2.47 (City of Akron) Description: Structural Steel Bolt Replacement Issues: Burden of proof, Contract interpretation/ambiguity, Means and methods, Workmanlike construction Decision/Recommendation: 04-060440-01
District 4 WOLF CREEK ENGINEERING AND CONTRACTING INC Year: 2008 Project Number: 060441 PID Number: 23702 Specification Year: 2005 Dispute/Claim Number: 04-060441-01 Dispute Resolution Forum: Director's Claim Board Location: SUM - SR 21 - (2.60 Greenwich Rd.) (4.62 Reimer Rd.) Description: Structural Steel Price Escalation due to Sole Source Issues: Burden of proof, Material escalation Decision/Recommendation: 04-060441-01
District 4 VELOTTA COMPANY Year: 2005 Project Number: 030534 PID Number: 21004 Specification Year: 2002 Dispute/Claim Number: 04-030534-01 Dispute Resolution Forum: Deputy Director's Board Location: POR - IR 76 - 9.50 Description: Fabrication of Structural Steel Plate Girders Issues: Constructive acceleration, Unjust enrichment, Equitable Adjustment, Early Completion Schedule, Mitigation, Duty to coordinate subs, Voluntary Acceleration Decision/Recommendation: 04-030534-01
District 4 SODA CONSTRUCTION COMPANY Year: 2002 Project Number: 990181 PID Number: 4130 Specification Year: 1997 Dispute/Claim Number: 04-0181(99)-01 Dispute Resolution Forum: Deputy Director's Board Location: MAH - S.R. 616 - 4.973 (City of Struthers) Description: Compensation for Breach of Contract, Misc. Decision/Recommendation: 04-0181(99)-01
District 4 ANTHONY ALLEGA CEMENT CONTRACTOR/GREAT LAKES CONST - JV Year: 2008 Project Number: 060002 PID Number: 6080 Specification Year: 2005 Dispute/Claim Number: 04-060002-01 Dispute Resolution Forum: Director's Claim Board Location: MAH - I R 80 - 0.97 Description: Industry Wide Claim Shortage Issues: Duty to coordinate subs, Industry-wide shortage/impacts Decision/Recommendation: 04-060002-01
District 4 VELOTTA COMPANY Year: 2008 Project Number: 030534 PID Number: 21004 Specification Year: 2002 Dispute/Claim Number: 04-030534-04 Dispute Resolution Forum: Director's Claim Board Location: POR - IR 76 - 9.50 Description: "Over Inspection" of Bridge Painting Issues: Bridge painting, Burden of proof, Changed contract condition Decision/Recommendation: 04-030534-04
District 4 VELOTTA COMPANY Year: 1999 Project Number: 940613 PID Number: 4185 Specification Year: Dispute/Claim Number: 04-0613(94)-01 Dispute Resolution Forum: Arbitration Location: Summit County Description: Additional Costs of Painting Operations, Excess Sandblasting, Excess Materials Issues: Bridge painting, Reasonably close conformity, Inspection Decision/Recommendation: 04-0613(94)-01
District 4 TRI SPAN CORPORATION Year: 2009 Project Number: 080001 PID Number: 77345 Specification Year: 2005 Dispute/Claim Number: 04-080001-01 Dispute Resolution Forum: Director's Claim Board Location: ATB - IR-90-5.37;ATB-46-21.95 Description: Additional Embankment Costs due to Improper Testing Issues: ODOT Testing Procedures, Inefficiency/Loss of productivity, Means and methods, Responsibility for project Decision/Recommendation: 04-080001-01
District 4 NORTHERN OHIO PAVING COMPANY Year: 2002 Project Number: 013002 PID Number: 22163 Specification Year: 1997 Dispute/Claim Number: 04-3002(01)-1119-04 Dispute Resolution Forum: Deputy Director's Board Location: TRU - IR 80 - 9.08 Description: Repair of Bridge Overlay Decision/Recommendation: 04-3002(01)-1119-04
District 4 VELOTTA COMPANY Year: 2008 Project Number: 030534 PID Number: 21004 Specification Year: 2002 Dispute/Claim Number: 04-030534-03 Dispute Resolution Forum: Director's Claim Board Location: POR - IR 76 - 9.50 Description: Form Safety Stop Removal Issues: Contract interpretation/ambiguity, Extra work Decision/Recommendation: 04-030534-03
District 4 GREAT LAKES CONSTRUCTION CO Year: 2003 Project Number: 000323 PID Number: 13458 Specification Year: 1997 Dispute/Claim Number: 04-0323(00)-1102-02 Dispute Resolution Forum: Deputy Director's Board Location: SUM - IR 76 - 24.799/0.000 (Cities of Akron & Tallmadge) Description: Thin Pavement Issues: Thin concrete pavement, Unjust enrichment Decision/Recommendation: 04-0323(00)-1102-02
District 4 GREAT LAKES CONSTRUCTION CO Year: 2003 Project Number: 000323 PID Number: 13458 Specification Year: 1997 Dispute/Claim Number: 04-0323(00)-1102-01 Dispute Resolution Forum: Deputy Director's Board Location: SUM - IR 76 - 24.799/0.000 (Cities of Akron & Tallmadge) Description: Concrete Pavement with Warranty Issues: Concrete pavement w/warranty Decision/Recommendation: 04-0323(00)-1102-01
District 4 VELOTTA COMPANY Year: 2008 Project Number: 030534 PID Number: 21004 Specification Year: 2002 Dispute/Claim Number: 04-030534-02 Dispute Resolution Forum: Arbitration Location: POR - IR 76 - 9.50 Description: Temporary Pavement Repairs Issues: Burden of proof, Contract interpretation/ambiguity Decision/Recommendation: 04-030534-02
District 4 SHELLY & SANDS INC Year: 2004 Project Number: 030406 PID Number: 23412 Specification Year: 2002 Dispute/Claim Number: 04-0406(03)-01 Dispute Resolution Forum: Deputy Director's Board Location: POR - SR 303 - 2.73 (City of Streetsboro) Description: Partial Depth Repairs Issues: Signif. change in scope/character of work, Partial Depth Pavement Repair Decision/Recommendation: 04-0406(03)-01
District 5 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 070138 PID Number: 77221 Specification Year: 2005 Dispute/Claim Number: 05-070138-01 Dispute Resolution Forum: Director's Claim Board Location: LIC - SR 161/37 - 6.65/10.25 Description: Value Engineering Issues: Contract interpretation/ambiguity, Contractor proposed change Decision/Recommendation: 05-070138-01
District 5 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2007 Project Number: 023005 PID Number: 19821 Specification Year: 1997 Dispute/Claim Number: 05-023005-03 Dispute Resolution Forum: Director's Claim Board Location: GUE - IR 77 - 7.54/7.68 Description: Significant Changes in the Scope of Work Issues: Reasonably close conformity, Signif. change in scope/character of work, Change order release/waiver, Unjust enrichment, Inspection Decision/Recommendation: 05-023005-03
District 5 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2000 Project Number: 970139 PID Number: 14143 Specification Year: Dispute/Claim Number: 05-0139(97)-0897-03 Dispute Resolution Forum: Director's Claim Board Location: COS - USR 36 - 27.54 Description: Pipe Removal Payment Issues: Contract interpretation/ambiguity, Pipe removal, Pre-bid question Decision/Recommendation: 05-0139(97)-0897-03
District 5 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2001 Project Number: 970139 PID Number: 14143 Specification Year: Dispute/Claim Number: 05-0139(97)-0897-03 Dispute Resolution Forum: Arbitration Location: COS - USR 36 - 27.54 Description: Pipe Removal Payment Issues: Contract interpretation/ambiguity, Pipe removal, Pre-bid question Decision/Recommendation: 05-0139(97)-0897-03
District 5 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2007 Project Number: 023005 PID Number: 19821 Specification Year: 1997 Dispute/Claim Number: 05-023005-02 Dispute Resolution Forum: Director's Claim Board Location: GUE - IR 77 - 7.54/7.68 Description: Bridge Painting - Painting Platform Issues: Contractor proposed change, Change order release/waiver, Notice, Mitigation, Duty to coordinate subs Decision/Recommendation: 05-023005-02
District 5 KOKOSING CONSTRUCTION COMPANY INC Year: 2004 Project Number: 020068 PID Number: 13281 Specification Year: 1997 Dispute/Claim Number: 05-0068(02)-01 Dispute Resolution Forum: Deputy Director's Board Location: FAI - USR 33 - 0.41 (City of Springdale) Description: Ameritech Utility Delay Issues: Utility delay, CPM Progress Schedule, Non-responsiveness as approval/acceptance, Overhead (home/field office), Extra work, Notice, Delay - critical/non-critical, CPM calendar/logic changes Decision/Recommendation: 05-0068(02)-01
District 5 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2007 Project Number: 023005 PID Number: 19821 Specification Year: 1997 Dispute/Claim Number: 05-023005-01 Dispute Resolution Forum: Director's Claim Board Location: GUE - IR 77 - 7.54/7.68 Description: Bridge Painting - High Profile Issues: Specifications (design/performance), Bridge painting, Past practice, Defective specification Decision/Recommendation: 05-023005-01
District 6 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2011 Project Number: 101039 PID Number: 80721 Specification Year: 2008 Dispute/Claim Number: 06-101039-01 Dispute Resolution Forum: Director's Claim Board Location: FRA - IR-270-37.04 Description: Method of Payment of Topsoil in a Median Planter Issues: Method of Measurement, Burden of proof Decision/Recommendation: 06-101039-01
District 6 NATIONAL ENGINEERING & CONTRACTING COMPANY Year: 2006 Project Number: 040163 PID Number: 77003 Specification Year: 2002 Dispute/Claim Number: 06-040163-03 Dispute Resolution Forum: Dispute Review Board Location: FRA - SR 161/IR 270-25.900/40.260-Part 1 & 2 (City of Columbus) Description: Multiple Project Impacts Issues: Inefficiency/Loss of productivity, Utility delay, Delay - owner caused, Constructive acceleration, Extra work, Change order release/waiver, Winter protection, Overhead (home/field office) Decision/Recommendation: 06-040163-03
District 6 NATIONAL ENGINEERING & CONTRACTING COMPANY Year: 2005 Project Number: 040163 PID Number: 77003 Specification Year: 2002 Dispute/Claim Number: 06-0163(04)-02 Dispute Resolution Forum: Dispute Review Board Location: FRA - SR 161/IR 270-25.900/40.260-Part 1 & 2 (City of Columbus) Description: MSE Wall Design Criteria Issues: Contract interpretation/ambiguity, MSE wall, Incorporation by reference Decision/Recommendation: 06-0163(04)-02
District 6 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2003 Project Number: 020069 PID Number: 4666 Specification Year: 1997 Dispute/Claim Number: 06-0069(02)-01 Dispute Resolution Forum: Deputy Director's Board Location: FRA - IR 670 - 3.17/Various - Part 1 & 2 (City of Columbus) Description: Drilled Shafts and Tie Backs Issues: Differing site conditions, Drilled shafts, Tie back retaining walls, Means and methods, Winter protection Decision/Recommendation: 06-0069(02)-01
District 6 NATIONAL ENGINEERING & CONTRACTING COMPANY Year: 2005 Project Number: 040163 PID Number: 77003 Specification Year: 2002 Dispute/Claim Number: 06-0163(04)-01 Dispute Resolution Forum: Dispute Review Board Location: FRA - SR 161/IR 270-25.900/40.260-Part 1 & 2 (City of Columbus) Description: MSE Wall Backfill Resistivity Testing Issues: Mutual Mistake, Unjust enrichment, Reasonably close conformity, Industry standard, Past practice, Contract interpretation/ambiguity, MSE wall Decision/Recommendation: 06-0163(04)-01
District 6 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2008 Project Number: 060162 PID Number: 75904 Specification Year: 2005 Dispute/Claim Number: 06-060162-01 Dispute Resolution Forum: Director's Claim Board Location: FRA - IR 71-7.68 (Hoover Rd.) Description: Pinholing Issues: Bridge painting, Defective specification, Duty to coordinate subs, Industry standard, Means and methods Decision/Recommendation: 06-060162-01
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2007 Project Number: 060264 PID Number: 77467 Specification Year: 2005 Dispute/Claim Number: 06-060264-01 Dispute Resolution Forum: Dispute Review Board Location: FRA - USR 62-14.11 (Main Street) Description: High Water Issues: Act of God, Contract interpretation/ambiguity Decision/Recommendation: 06-060264-01
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-03 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: Contractor is seeking $223, 560 for home and field overhead for the winter of 2006/2007. This was a workday contract rather than a completion date contract. Issues: Delay - owner caused, Overhead (home/field office) Decision/Recommendation: 06-040294-03
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-02 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: Asphalt for MOT - contractor is seeking payment for asphalt used to transition between pavements at different elevations. Issues: Contract interpretation/ambiguity Decision/Recommendation: 06-040294-02
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-04 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: This project was sold with no provision for a fuel price adjustment. In 2005 ODOT established a fuel price adjustment policy and allowed for such adjustments on ongoing projects and extended that until 2006. The Contractor is asking for the adjustment for work it did in 2007. Issues: Delay - owner caused, Industry standard, Material escalation Decision/Recommendation: 06-040294-04
District 6 NATIONAL ENGINEERING & CONTRACTING COMPANY Year: 2010 Project Number: 040163 PID Number: 77003 Specification Year: 2002 Dispute/Claim Number: 06-040163-07 Dispute Resolution Forum: Director's Claim Board Location: FRA - SR 161/IR 270-25.900/40.260-Part 1 & 2 (City of Columbus) Description: Failure of 1500 mm pipe Issues: Workmanlike construction, Defective specification, Delay - owner caused, Pipe removal Decision/Recommendation: 06-040163-07
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-05 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: Material escalation for steel and geo-textile fabric. When project was bid these materials were experiencing large price escalations. Due to this volatility price quotes for this material were only firm through 9/30/04 for piling and 12/31/05 for the geotextile fabric. The contractor was delayed 45 days due to extra work. Issues: Material escalation, Industry standard Decision/Recommendation: 06-040294-05
District 6 SHELLY & SANDS INC Year: 2013 Project Number: 110341 PID Number: 76191 Specification Year: 2010 Dispute/Claim Number: 06-110341-01 Dispute Resolution Forum: Director's Claim Board Location: FRA - IR-270-2.60 Description: Shop Applied Paint Issues: Acceptance (express/implied), Bridge painting, Burden of proof, Duty to coordinate subs, ODOT Testing Procedures Decision/Recommendation: 06-110341-01
District 6 SHELLY & SANDS INC Year: 2011 Project Number: 080080 PID Number: 81190 Specification Year: 2005 Dispute/Claim Number: 06-080080-01 Dispute Resolution Forum: Director's Claim Board Location: PIC - US-23-10.38 AND VARIOUS Description: Railroad Delay Issues: Burden of proof, Inefficiency/Loss of productivity, Railroad Conflict Decision/Recommendation: 06-080080-01
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2008 Project Number: 060264 PID Number: 77467 Specification Year: 2005 Dispute/Claim Number: 06-060264-03 Dispute Resolution Forum: Dispute Review Board Location: FRA - USR 62-14.11 (Main Street) Description: Transportation Delay Claim Issues: Delay - owner caused, Means and methods, Past practice Decision/Recommendation: 06-060264-03
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-06 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: This project used a workday contract in lieu of a completion date contract. Parties agree to 45 days of extra work and 102 days of weather. Kokosing is seeking site rental costs for land leased for their portable plant ($8,727.12) and for labor escalation ($10,182.05) for extension of the contract into 2007. Issues: Delay - owner caused, Material escalation Decision/Recommendation: 06-040294-06
District 6 NATIONAL ENGINEERING & CONTRACTING COMPANY Year: 2010 Project Number: 040163 PID Number: 77003 Specification Year: 2002 Dispute/Claim Number: 06-040163-09 Dispute Resolution Forum: Director's Claim Board Location: FRA - SR 161/IR 270-25.900/40.260-Part 1 & 2 (City of Columbus) Description: Failing Epoxy Urethane Sealer Issues: Defective specification, Workmanlike construction, Precaution against damage Decision/Recommendation: 06-040163-09
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-07 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: Extra costs to "level up" median embankment - an error in the plan caused an elevation differential that had to be eliminated by embankment to prevent a drop off. District stated almost none of the median had been acceptably final graded. District also stated the operation of grading no different in planned profile areas vs. changed profile areas. Contractor presented a measured mile approach to show inefficiency. Issues: Signif. change in scope/character of work Decision/Recommendation: 06-040294-07
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-01 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: Interest on untimely processing of Change Orders 60, 63 and 65. Issues: Interest, Change order policy Decision/Recommendation: 06-040294-01
District 6 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 040294 PID Number: 77118 Specification Year: 2002 Dispute/Claim Number: 06-040294-08 Dispute Resolution Forum: Director's Claim Board Location: CLA - IR 70-25.11/28.95/29.32/0.00 - Part 1, 2 & 3 Description: Contractor wants paid permanent seeding for additional locations: two off-site waste areas, an off-site area where temporary plant was located and an area it placed waste within the highway ROW. Areas totalled 69,819 SY. Issues: Contract interpretation/ambiguity, Discrepancy in quantity Decision/Recommendation: 06-040294-08
District 6 JOHN R JURGENSEN COMPANY Year: 2006 Project Number: 030134 PID Number: 6225 Specification Year: 1997 Dispute/Claim Number: n/a Dispute Resolution Forum: Location: FAY - IR 71 - 0.00 (Villages of Octa & Jeffersonville) Description: High Performance Concrete For New Bridge Decks With Warranty Appeal Issues: Warranty Decision/Recommendation: n/a
District 6 Perram Electric Year: 2012 Project Number: 100345 PID Number: 87884 Specification Year: 2010 Dispute/Claim Number: 12-100389-01 Dispute Resolution Forum: Director's Claim Board Location: District 6 various Description: Pole Clamps for Tether Wire
District 7 R B JERGENS CONTRACTORS INC Year: 2013 Project Number: 091060 PID Number: 80236 Specification Year: 2008 Dispute/Claim Number: 07-091060-02 Dispute Resolution Forum: Director's Claim Board Location: MOT - LR-SOUTH DIXIE-PHASE 2 Description: Final Quantity Dispute - 304 base and asphalt surface course Issues: Discrepancy in quantity, Signif. change in scope/character of work, Means and methods Decision/Recommendation: 07-091060-02
District 7 KOKOSING CONSTRUCTION COMPANY INC Year: 2004 Project Number: 010560 PID Number: 18249 Specification Year: 1997 Dispute/Claim Number: 07-0560(01)-01 Dispute Resolution Forum: Deputy Director's Board Location: MOT - IR 75-29.305 Description: Ameritech Utility Delay Issues: Utility delay, Mitigation, Notice, CPM Progress Schedule Decision/Recommendation: 07-0560(01)-01
District 7 R B JERGENS CONTRACTORS INC Year: 2011 Project Number: 091060 PID Number: 80236 Specification Year: 2008 Dispute/Claim Number: 07-091060-01 Dispute Resolution Forum: Director's Claim Board Location: MOT - LR-SOUTH DIXIE-PHASE 2 Description: Delays - due to utility - due to ODOT delay in scheduling pre-con - due to poor subgrade Issues: Delay - owner caused, Overhead (home/field office), Burden of proof, CPM Progress Schedule, Utility delay Decision/Recommendation: 07-091060-01
District 7 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 060036 PID Number: 17067 Specification Year: 2005 Dispute/Claim Number: 07-060036-02 Dispute Resolution Forum: Director's Claim Board Location: MOT - USR 35-15.07 Description: Early Notice of Excessive & Improper Enforcement Issues: Dispute Resolution Process, Notice, Overhead (home/field office), Signif. change in scope/character of work Decision/Recommendation: 07-060036-02
District 7 KOKOSING CONSTRUCTION COMPANY INC Year: 2007 Project Number: 030100 PID Number: 19070 Specification Year: 1997 Dispute/Claim Number: 07-030100-01 Dispute Resolution Forum: Director's Claim Board Location: MOT - IR 75 - 31.842 (City of Vandalia) Description: Bridge Painting - Pinholing Issues: Contract interpretation/ambiguity, Reasonably close conformity, Defective specification, Workmanlike construction, Bridge painting, Past practice Decision/Recommendation: 07-030100-01
District 7 KOKOSING CONSTRUCTION COMPANY INC Year: 2009 Project Number: 070387 PID Number: 75927 Specification Year: 2005 Dispute/Claim Number: 07-070387-01 Dispute Resolution Forum: Dispute Review Board Location: MOT - IR-75-13.11 Description: Sleeper Slab Concrete and Coping Issues: Contract interpretation/ambiguity, Means and methods, Mitigation, Pre-bid question Decision/Recommendation: 07-070387-01
District 8 DOUBLE Z CONSTRUCTION COMPANY Year: 2008 Project Number: 050497 PID Number: 22379 Specification Year: 2005 Dispute/Claim Number: 08-050497-01 Dispute Resolution Forum: Director's Claim Board Location: CLE - USR 52-7.81/15.44/20.67 Description: Unclassified Excavation Issues: Contract interpretation/ambiguity, Discrepancy in quantity, Errors and Omissions Decision/Recommendation: 08-050497-01
District 8 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2002 Project Number: 010158 PID Number: 6525 Specification Year: 1997 Dispute/Claim Number: 08-0158(01)-0102-01 Dispute Resolution Forum: Deputy Director's Board Location: HAM - SR 4-4.000 (Paddock Road) (City of Cincinnati) Description: Extent of Repair/Removal of Honeycomb Concrete Decision/Recommendation: 08-0158(01)-0102-01
District 8 JOHN R JURGENSEN COMPANY Year: 2000 Project Number: 003012 PID Number: 19786 Specification Year: 1997 Dispute/Claim Number: 08-3012(00)-0201-02 Dispute Resolution Forum: Arbitration Location: HAM - IR 275 - 32.27/0.00 (Cities of Montgomery & Milford) (Village of Indian Hill) Description: Design-Build Scope of Work - Temporary Shoring Issues: Design-Build, Specifications (design/performance), Contract interpretation/ambiguity Decision/Recommendation: 08-3012(00)-0201-02
District 8 JOHN R JURGENSEN COMPANY Year: 2005 Project Number: 030002 PID Number: 17381 Specification Year: 1997 Dispute/Claim Number: 08-030002-01 Dispute Resolution Forum: Director's Claim Board Location: BUT - CR 115 - 0.00 (City of Fairfield) Description: Concrete Testing and Inspection Issues: Notice, Duty to examine Bid Documents, Errors and Omissions, Contract interpretation/ambiguity, Signif. change in scope/character of work, Mitigation, Duty to coordinate subs, Equitable Adjustment Decision/Recommendation: 08-030002-01
District 8 A & A SAFETY INC Year: 2013 Project Number: 120233 PID Number: 87018 Specification Year: 2010 Dispute/Claim Number: 08-120233-01 Dispute Resolution Forum: Director's Claim Board Location: BUT - VA-PM/RPM-FY2012 Description: Center Line Marking Final Quantity Issues: Contract interpretation/ambiguity, Method of Measurement, Past practice Decision/Recommendation: 08-120233-01
District 9 ALAN STONE CO INC Year: 2013 Project Number: 120251 PID Number: 91276 Specification Year: 2010 Dispute/Claim Number: 09-120251-01 Dispute Resolution Forum: Director's Claim Board Location: LAW - SR-378-0.20 Description: Water in Drilled Shafts Issues: Drilled shafts, Differing site conditions, Interest, Contract interpretation/ambiguity Decision/Recommendation: 09-120251-01
District 9 C J MAHAN CONSTRUCTION COMPANY LLC Year: 2008 Project Number: 010178 PID Number: 11858 Specification Year: Dispute/Claim Number: 09-010178-02 Dispute Resolution Forum: Arbitration Location: SCI - USR 23-0.00 (City of Portsmouth) Description: Baffle Plate Dispute Issues: Contract interpretation/ambiguity, Acceptance (express/implied) Decision/Recommendation: 09-010178-02
District 9 ICARUS INDUSTRIAL PAINTING & CONTRACTING CO INC Year: 2002 Project Number: 990465 PID Number: 19781 Specification Year: 1997 Dispute/Claim Number: 09-0465(99)-01 Dispute Resolution Forum: Deputy Director's Board Location: JAC - S.R. 32 - 11.75/VARIOUS (City of Ironton) (Village of Hanging Rock) Description: Bridge Painting Issues: Dispute Resolution Process, Bridge painting Decision/Recommendation: 09-0465(99)-01
District 9 C J MAHAN CONSTRUCTION COMPANY LLC Year: 2002 Project Number: 010178 PID Number: 11858 Specification Year: 1997 Dispute/Claim Number: 09-0178(01)-01 Dispute Resolution Forum: Deputy Director's Board Location: SCI - USR 23-0.00 (City of Portsmouth) Description: Erection Engineering Delay and Cost Issues: CPM Progress Schedule, Delay - owner caused, Errors and Omissions Decision/Recommendation: 09-0178(01)-01
District 10 R C CONSTRUCTION COMPANY AND SON INC Year: 2008 Project Number: 060322 PID Number: 76229 Specification Year: 2005 Dispute/Claim Number: 10-060322-01 Dispute Resolution Forum: Director's Claim Board Location: VIN - USR 50-0.10 Description: Off Site Borrow Issues: Burden of proof, Entitlement agreed/damages in dispute, Inefficiency/Loss of productivity, Means and methods Decision/Recommendation: 10-060322-01
District 10 MAHAN/NATIONAL A JOINT VENTURE Year: 2009 Project Number: 020510 PID Number: 19714 Specification Year: 1997 Dispute/Claim Number: 10-020510-01 Dispute Resolution Forum: Director's Claim Board Location: MEG - USR 33-15.70 (Village of Pomeroy) Description: P-T Air Testing Quantum Only Issues: CPM calendar/logic changes, Delay - critical/non-critical, Delay - owner caused, Entitlement agreed/damages in dispute, Mutual Mistake Decision/Recommendation: 10-020510-01
District 10 BEAVER EXCAVATING COMPANY Year: 2008 Project Number: 060132 PID Number: 75812 Specification Year: 2005 Dispute/Claim Number: 10-060132-01 Dispute Resolution Forum: Director's Claim Board Location: MEG - USR 33-9.40; SR 7-6.17 - Part 1 & 2 Description: Concrete Pavement Cracking Issues: Defective specification, Contractor proposed change, Means and methods, Specifications (design/performance) Decision/Recommendation: 10-060132-01
District 10 SMITH & JOHNSON CONSTRUCTION CO Year: 2004 Project Number: 010246 PID Number: 18288 Specification Year: 1997 Dispute/Claim Number: 10-0246(01)-0402-02 Dispute Resolution Forum: Director's Claim Board Location: ATH - USR 33 - 40.981 Description: Timber Value & Production Loss Decision/Recommendation: 10-0246(01)-0402-02
District 10 MAHAN/NATIONAL A JOINT VENTURE Year: 2007 Project Number: 020510 PID Number: 19714 Specification Year: 1997 Dispute/Claim Number: 10-020510-01 Dispute Resolution Forum: Dispute Review Board Location: MEG - USR 33-15.70 (Village of Pomeroy) Description: Post tension duct air test specification Issues: Changed contract condition Decision/Recommendation: 10-020510-01
District 10 MAHAN/NATIONAL A JOINT VENTURE Year: 2006 Project Number: 020510 PID Number: 19714 Specification Year: 1997 Dispute/Claim Number: 10-020510-02 Dispute Resolution Forum: Dispute Review Board Location: MEG - USR 33-15.70 (Village of Pomeroy) Description: Tower Leg Concrete Issues: Defective specification, Means and methods, Workmanlike construction, Burden of proof, Changed contract condition Decision/Recommendation: 10-020510-02
District 10 BECDIR CONSTRUCTION COMPANY Year: 2004 Project Number: 020236 PID Number: 23900 Specification Year: 1997 Dispute/Claim Number: 10-0236(02)-01 Dispute Resolution Forum: Arbitration Location: VIN - CR 38A - 0.36/Various Description: Covered Bridges Issues: Constructive acceleration, Mitigation, Precaution against damage, Act of God, Dispute Resolution Process, Claim after final change order, Inefficiency/Loss of productivity, Delay - owner caused Decision/Recommendation: 10-0236(02)-01
District 10 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2003 Project Number: 013001 PID Number: 21053 Specification Year: 1997 Dispute/Claim Number: 10-3001(01)-1001-04 Dispute Resolution Forum: Director's Claim Board Location: ATH - USR 33 - 10.41 Description: Project Completion Delay - HOOH, Extended Cost Issues: Engineer-ordered suspension, Inefficiency/Loss of productivity, Overhead (home/field office), Extra work, Change order policy, Interest Decision/Recommendation: 10-3001(01)-1001-04
District 10 MAHAN/NATIONAL A JOINT VENTURE Year: 2009 Project Number: 020510 PID Number: 19714 Specification Year: 1997 Dispute/Claim Number: 10-020510-4 and 5 Dispute Resolution Forum: Deputy Director's Board Location: MEG - USR 33-15.70 (Village of Pomeroy) Description: Retaining Wall Concrete Quantity and Retaining Wall Sealing Quantity Issues: Contract interpretation/ambiguity, Contractor proposed change, Discrepancy in quantity Decision/Recommendation: 10-020510-4 and 5
District 10 COMPLETE GENERAL CONSTRUCTION COMPANY Year: 2002 Project Number: 013001 PID Number: 21053 Specification Year: 1997 Dispute/Claim Number: 10-3001(01)-1001-04 Dispute Resolution Forum: Deputy Director's Board Location: ATH - USR 33 - 10.41 Description: Project Completion Delay - HOOH, Extended Cost Issues: Engineer-ordered suspension, Extra work, Change order policy, Interest, Inefficiency/Loss of productivity Decision/Recommendation: 10-3001(01)-1001-04
District 10 SMITH & JOHNSON CONSTRUCTION CO Year: 2002 Project Number: 010246 PID Number: 18288 Specification Year: 1997 Dispute/Claim Number: 10-0246(01)-0402-02 Dispute Resolution Forum: Deputy Director's Board Location: ATH - USR 33 - 40.981 Description: Timber Value & Production Loss Decision/Recommendation: 10-0246(01)-0402-02
District 10 MAHAN/NATIONAL A JOINT VENTURE Year: 2007 Project Number: 020510 PID Number: 19714 Specification Year: 1997 Dispute/Claim Number: 10-020510-02 Dispute Resolution Forum: Dispute Review Board Location: MEG - USR 33-15.70 (Village of Pomeroy) Description: Concrete Quality in Tower Segment Four Decision/Recommendation: 10-020510-02
District 11 SHELLY & SANDS INC Year: 2010 Project Number: 091002 PID Number: 84342 Specification Year: 2008 Dispute/Claim Number: 11-091002-01 Dispute Resolution Forum: Director's Claim Board Location: HAS - SR-9-9.38 Description: Disposition of Improperly Placed RPMs Issues: Workmanlike construction, Acceptance (express/implied), Past practice Decision/Recommendation: 11-091002-01
District 11 CENTRAL-ALLIED ENTERPRISES INC Year: 2010 Project Number: 090139 PID Number: 25545 Specification Year: 2008 Dispute/Claim Number: 11-090139-01 Dispute Resolution Forum: Director's Claim Board Location: COL - US-62-4.86 Description: Disposition of Improperly Place RPMs Issues: Past practice, Workmanlike construction, Acceptance (express/implied) Decision/Recommendation: 11-090139-01
District 11 A P O'HORO COMPANY Year: 2010 Project Number: 080618 PID Number: 80116 Specification Year: 2008 Dispute/Claim Number: 11-080618-01 Dispute Resolution Forum: Director's Claim Board Location: COL - SR-164-21.81 Description: Method of Measurement of Composite Fiber Wrap System Issues: Contract interpretation/ambiguity, Duty to examine Bid Documents, Past practice Decision/Recommendation: 11-080618-01
District 12 KOKOSING CONSTRUCTION COMPANY INC Year: 2008 Project Number: 060372 PID Number: 5394 Specification Year: 2005 Dispute/Claim Number: 12-060372-02 Dispute Resolution Forum: Dispute Review Board Location: CUY - Fulton Road (BR-251) (City of Cleveland) Description: Post Tensioning Duct Air Testing Issues: Contract interpretation/ambiguity, Contractor proposed change, Specifications (design/performance) Decision/Recommendation: 12-060372-02
District 12 RUHLIN COMPANY Year: 2012 Project Number: 101041 PID Number: 86257 Specification Year: 2008 Dispute/Claim Number: 12-101041-01 Dispute Resolution Forum: Director's Claim Board Location: CUY - LR-WILLOW AVENUE LIFT BRIDGE Description: Aluminum Post modifications Issues: Duty to examine Bid Documents, Errors and Omissions, Shop Drawings Decision/Recommendation: 12-101041-01
District 12 GERONIMO PAINTING CO INC Year: 2009 Project Number: 050107 PID Number: 22130 Specification Year: 2002 Dispute/Claim Number: 12-050107-02 Dispute Resolution Forum: Director's Claim Board Location: CUY - SR 2 - 14.41 (City of Cleveland) Description: Testing Equipment Issues: Inspection, Reasonably close conformity, Entitlement agreed/damages in dispute, Inefficiency/Loss of productivity Decision/Recommendation: 12-050107-02
District 12 KARVO PAVING COMPANY Year: 2010 Project Number: 070080 PID Number: 19181 Specification Year: 2005 Dispute/Claim Number: 12-070080-02 Dispute Resolution Forum: Director's Claim Board Location: GEA - USR 422 - 18.31/0.00 Description: Bridge Deck Repair Costs Issues: ODOT Testing Procedures, Responsibility for project Decision/Recommendation: 12-070080-02
District 12 ANTHONY ALLEGA CEMENT CONTRACTOR INC Year: 2008 Project Number: 078007 PID Number: 22907 Specification Year: Dispute/Claim Number: 12-078007-01 Dispute Resolution Forum: Director's Claim Board Location: LAK - SR 86 - 1.32 Description: Foundation Rock Socket Issues: Differing site conditions, Workmanlike construction Decision/Recommendation: 12-078007-01
District 12 BURTON SCOT CONTRACTORS LLC Year: 2012 Project Number: 100186 PID Number: 80252 Specification Year: 2008 Dispute/Claim Number: 12-100186-01 Dispute Resolution Forum: Director's Claim Board Location: CUY - SR-43-6.18 Description: Home Office Overhead and Inefficiency Issues: Changed contract condition, Inefficiency/Loss of productivity, Delay - owner caused, Notice, Signif. change in scope/character of work, Utility delay Decision/Recommendation: 12-100186-01
District 12 SHELLY COMPANY Year: 2007 Project Number: 060121 PID Number: 12996 Specification Year: 2005 Dispute/Claim Number: 12-060121-01 Dispute Resolution Forum: Director's Claim Board Location: CUY - IR 271-6.04 Description: Asphalt concrete bump grinding and mix design changes Issues: Specifications (design/performance), Means and methods Decision/Recommendation: 12-060121-01
District 12 ANTHONY ALLEGA CEMENT CONTRACTOR/GREAT LAKES CONST - JV Year: 2010 Project Number: 080597 PID Number: 13486 Specification Year: 2008 Dispute/Claim Number: 12-080597-05 Dispute Resolution Forum: Director's Claim Board Location: LAK - SR-2-3.32 Description: Dowel Bar Inserter Spec Change Issues: Means and methods, Contract interpretation/ambiguity, Acceptance (express/implied), Past practice Decision/Recommendation: 12-080597-05
District 12 RUHLIN COMPANY Year: 2012 Project Number: 101041 PID Number: 86257 Specification Year: 2008 Dispute/Claim Number: 12-101041-03 Dispute Resolution Forum: Director's Claim Board Location: CUY - LR-WILLOW AVENUE LIFT BRIDGE Description: Repair Costs for Shop Coating Defects Issues: Reasonably close conformity, Inspection, Acceptance (express/implied), Bridge painting Decision/Recommendation: 12-101041-03
District 12 GERONIMO PAINTING CO INC Year: 2006 Project Number: 050107 PID Number: 22130 Specification Year: 2002 Dispute/Claim Number: 12-050107-03 Dispute Resolution Forum: Deputy Director's Board Location: CUY - SR 2 - 14.41 (City of Cleveland) Description: Bridge Painting - Heating Costs Issues: Defective specification, Notice, Mitigation Decision/Recommendation: 12-050107-03
District 12 WALSH CONSTRUCTION COMPANY Year: 2006 Project Number: 040293 PID Number: 5511 Specification Year: 1997 Dispute/Claim Number: 12-040293-01 Dispute Resolution Forum: Director's Claim Board Location: CUY - West 3rd St. (City of Cleveland) Description: Wire Rope Length Issues: Disclaimer, Errors and Omissions, Shop Drawings, Acceptance (express/implied), Defective specification, Notice, Mitigation Decision/Recommendation: 12-040293-01
District 12 RUHLIN COMPANY Year: 2012 Project Number: 101041 PID Number: 86257 Specification Year: 2008 Dispute/Claim Number: 12-101041-02 Dispute Resolution Forum: Director's Claim Board Location: CUY - LR-WILLOW AVENUE LIFT BRIDGE Description: Sidewalk Bracket and Connection Angles Issues: Contract interpretation/ambiguity Decision/Recommendation: 12-101041-02
District 12 GREAT LAKES CONSTRUCTION CO Year: 2011 Project Number: 080598 PID Number: 21272 Specification Year: 2005 Dispute/Claim Number: 12-080598-02 Dispute Resolution Forum: Director's Claim Board Location: CUY - SR-237-4.93 - PART I (FRONT STREET); CUY-237-4.55 - PART 2 Description: Railroad Delay - Crane holding girder over live track Issues: Burden of proof, Delay - critical/non-critical, Inefficiency/Loss of productivity, Railroad Conflict Decision/Recommendation: 12-080598-02
District 12 ANTHONY ALLEGA CEMENT CONTRACTOR/GREAT LAKES CONST - JV Year: 2010 Project Number: 080597 PID Number: 13486 Specification Year: 2008 Dispute/Claim Number: 12-080597-03 Dispute Resolution Forum: Director's Claim Board Location: LAK - SR-2-3.32 Description: SS888 Aggregate mix design Issues: Defective specification, Duty to examine Bid Documents, Contract interpretation/ambiguity Decision/Recommendation: 12-080597-03
District 12 GERONIMO PAINTING CO INC Year: 2006 Project Number: 050107 PID Number: 22130 Specification Year: 2002 Dispute/Claim Number: 12-050107-01 Dispute Resolution Forum: Deputy Director's Board Location: CUY - SR 2 - 14.41 (City of Cleveland) Description: Bridge Painting - Surface Cleanliness Issues: Inspection, Acceptance (express/implied), Industry standard, Contract interpretation/ambiguity, Mitigation, Bridge painting Decision/Recommendation: 12-050107-01
District 12 ANTHONY ALLEGA CEMENT CONTRACTOR/GREAT LAKES CONST - JV Year: 2010 Project Number: 080597 PID Number: 13486 Specification Year: 2008 Dispute/Claim Number: 12-080597-02 Dispute Resolution Forum: Director's Claim Board Location: LAK - SR-2-3.32 Description: Excavation of Subgrade - plans show excavation in one area - ODOT ordered work done in different area Issues: Signif. change in scope/character of work, Inefficiency/Loss of productivity, Entitlement agreed/damages in dispute Decision/Recommendation: 12-080597-02
District 12 GERONIMO PAINTING CO INC Year: 2006 Project Number: 050107 PID Number: 22130 Specification Year: 2002 Dispute/Claim Number: 12-050107-02 Dispute Resolution Forum: Deputy Director's Board Location: CUY - SR 2 - 14.41 (City of Cleveland) Description: Bridge Painting - Testing Equipment Issues: Contract interpretation/ambiguity, Inspection, Industry standard, Bridge painting Decision/Recommendation: 12-050107-02
District 12 ANTHONY ALLEGA CEMENT CONTRACTOR/GREAT LAKES CONST - JV Year: 2010 Project Number: 080597 PID Number: 13486 Specification Year: 2008 Dispute/Claim Number: 12-080597-06 Dispute Resolution Forum: Director's Claim Board Location: LAK - SR-2-3.32 Description: Additional Costs for Compaction of 304 Material Issues: Inspection, Changed contract condition, Precaution against damage Decision/Recommendation: 12-080597-06
District 12 KARVO PAVING COMPANY Year: 2010 Project Number: 070002 PID Number: 12999 Specification Year: 2005 Dispute/Claim Number: 12-070002-01 Dispute Resolution Forum: Director's Claim Board Location: CUY - IR 480 - 6.78 (Cities of Brookpark, Cleveland & Fairview Park) Description: Repair of cracks in concrete pavement (ramp) Issues: Workmanlike construction, Burden of proof Decision/Recommendation: 12-070002-01
District 12 GERONIMO PAINTING CO INC Year: 2006 Project Number: 050107 PID Number: 22130 Specification Year: 2002 Dispute/Claim Number: 12-050107-04 Dispute Resolution Forum: Director's Claim Board Location: CUY - SR 2 - 14.41 (City of Cleveland) Description: Fuel Price Escalation Issues: Material escalation Decision/Recommendation: 12-050107-04
District 12 KARVO PAVING COMPANY Year: 2010 Project Number: 070080 PID Number: 19181 Specification Year: 2005 Dispute/Claim Number: 12-070080-02 Dispute Resolution Forum: Director's Claim Board Location: GEA - USR 422 - 18.31/0.00 Description: Replacement of Deck Wearing Surface due to failing material Issues: Inspection, Non-responsiveness as approval/acceptance, Responsibility for project District 12 ANTHONY ALLEGA CEMENT CONTRACTOR/GREAT LAKES CONST - JV Year: 2010 Project Number: 080597 PID Number: 13486 Specification Year: 2008 Dispute/Claim Number: 12-080597-02 Dispute Resolution Forum: Director's Claim Board Location: LAK - SR-2-3.32 Description: Excavation of Subgrade Issues: Changed contract condition, Equitable Adjustment, Inefficiency/Loss of productivity Decision/Recommendation: 12-080597-02
District 12 WALSH CONSTRUCTION COMPANY Year: 2008 Project Number: 040293 PID Number: 5511 Specification Year: 1997 Dispute/Claim Number: 12-040293-02 Dispute Resolution Forum: Director's Claim Board Location: CUY - West 3rd St. (City of Cleveland) Description: Increased Rigging Costs Issues: Changed contract condition, Extra work, Entitlement agreed/damages in dispute Decision/Recommendation: 12-040293-02
District 12 WALSH CONSTRUCTION COMPANY Year: 2008 Project Number: 040293 PID Number: 5511 Specification Year: 1997 Dispute/Claim Number: 12-040293-03 Dispute Resolution Forum: Director's Claim Board Location: CUY - West 3rd St. (City of Cleveland) Description: Increased Cleaning Costs Issues: Changed contract condition, Entitlement agreed/damages in dispute, Signif. change in scope/character of work Decision/Recommendation: 12-040293-03
District 12 RUHLIN COMPANY Year: 2013 Project Number: 101041 PID Number: 86257 Specification Year: 2008 Dispute/Claim Number: 12-101041-06 Dispute Resolution Forum: Director's Claim Board Location: CUY - LR-WILLOW AVENUE LIFT BRIDGE Description: Deficient Grating Installation (Open Grid Deck Welding) Issues: Contract interpretation/ambiguity, Industry standard, Reasonably close conformity Decision/Recommendation: 12-101041-06