Court Opinion

ID: 2734444
Source: CourtListenerOpinion
Date Created: 2014-09-19 01:17:57.018783+00
Date Added: 2024-06-11T12:40:21.036810
License: Public Domain

ARMED SERVICES BOARD OF CONTRACT APPEALS

Appeal of--                                 )
                                            )
GSC Construction, Inc.                      )      ASBCA No. 58747
                                            )
Under Contract No. N69450-07-C-l 770        )

APPEARANCES FOR THE APPELLANT:                     William A. Scott, Esq.
                                                   Francis M. Ervin, II, Esq.
                                                   Dane J. Sowinski, Esq.
                                                    Rogers Townsend & Thomas, PC
                                                    Charleston, SC

APPEARANCES FOR THE GOVERNMENT:                    Ronald J. Borro, Esq.
                                                    Navy Chief Trial Attorney
                                                   Stephanie Cates-Hannan, Esq.
                                                    Assistant Director
                                                   Rawn M. James, Jr., Esq.
                                                    Trial Attorney

                OPINION BY ADMINISTRATIVE JUDGE PEACOCK
              ON APPELLANT'S MOTION FOR SUMMARY JUDGMENT

       This appeal involves a challenge to the Navy's final performance evaluation under
the captioned contract to construct a medical clinic. The appeal has been consolidated
with two other appeals (ASBCA Nos. 58496 and 58748) involving numerous claim items
relating to performance of the contract cumulatively totaling in excess of $4.6 million.
ASBCA Nos. 58496 and 58748 are referenced hereinafter collectively as the companion
appeals. Appellant moves for summary judgment in ASBCA No. 58747 and the Navy
opposes. We deny the motion.

         STATEMENT OF FACTS FOR THE PURPOSES OF THE MOTION

        1. The Naval Facilities Engineering Command (NAVF AC) Southeast awarded
Contract No. N69450-07-C-l 770 to GSC Construction, Inc., (GSC) on 28 December
2006, in the amount of $41,590,506 for the construction of a consolidated medical clinic
at the Naval Weapons Station in Goose Creek, South Carolina (R4, tab 11at3219, 3221).
The contract established an original completion date of 27 January 2009 (R4, tab 11
at 3224). Modification No. P00047 extended the completion date until 21 July 2010 (R4,
tab 58 at 3384).
       2. NAVFAC prepared a final performance evaluation dated 23 February 2011,
indicating that GSC's work was accepted on 6 August 2010. The evaluation rated GSC's
overall performance as marginal. Although GSC's performance was rated satisfactory in
many areas, it was rated unsatisfactory in five areas and marginal in eight areas. (App.
mot., appx. at 18-20)

      3. GSC's Vice President, expressed its disagreement with the final evaluation in
an 18 March 2011 letter to the contracting officer (CO), alleging various factual and
procedural errors (app. mot., appx. at 21-24). The Navy disputes these errors.

       4. The CO issued a second final performance evaluation rating GSC's
performance marginal on 20 May 2011 adopting the conclusions of the earlier evaluation
(supp. R4, tab 216 at 2, 7). There are factual disputes concerning the authorship and
significance of certain remarks inserted in the final performance evaluation (supp. R4,
tab 216 at 4-7; see app. mot., appx. at 3-9, 21; gov't opp'n, ex. A, Fichter decl. ~ 4).

       5. GSC submitted an 18 September 2012 claim to the CO challenging the final
performance evaluation. GSC's claim alleged that the final performance evaluation was
not performed in accordance with the Federal Acquisition Regulation (FAR) and
pertinent NA VF AC Instructions. GSC also maintained that the factual analysis and
conclusions in the final performance evaluation were clearly erroneous and arbitrary and
capricious because the Navy failed to consider the adverse impact of changes, disputed
work, defective specifications, and the Navy's administration of the contract on the
contract work and schedule which form the subject matter of the companion appeals.
(Supp. R4, tab 214)

       6. GSC appealed the deemed denial of its claim by notice of appeal dated 21 June
2013. The Board docketed the appeal as ASBCA No. 58747. The consolidated companion
appeals involve claims under the captioned contract totaling in excess of $4,600,000. The
claims in ASBCA No. 58496 alone consist of approximately 20 sub-items involving
numerous aspects of the work, alleged delays and assertions of entitlement to unabsorbed
overhead.

                                        DECISION

        In moving for summary judgment, GSC raises two principal issues: (1) whether
the Navy failed to follow applicable regulations, policies, and procedures in preparing its
final performance evaluation, and (2) whether the final performance evaluation is
inaccurate, clearly erroneous, and arbitrary and capricious (app. mot. at 1).

      Summary judgment is only appropriate where the movant establishes that there is
no genuine issue as to any material fact and that it is entitled to judgment as a matter of
law. Mingus Constructors, Inc. v. United States, 812 F.2d 1387, 1390 (Fed. Cir. 1987).

                                             2
The record is replete with genuine issues of material fact which we need only address
summarily in denying this motion.

        GSC first alleges that the Navy committed procedural violations in the preparation
and dissemination of the final performance evaluation. The Navy disputes the alleged
violations and contends that, regardless of whether procedural violations occurred,
appellant has failed to offer any proof that it was prejudiced as a result thereof. We
agree. To prevail, GSC must show that the performance evaluation would have been
more favorable but for the purported procedural violations. Todd Constr., L.P. v. United
States, 656 F.3d 1306, 1316 (Fed. Cir. 2011). Assuming solely for purposes of argument
that one or more procedural violations occurred, GSC's motion wholly fails to proffer
uncontested facts establishing that the Navy's violations had any substantive adverse
impact on the ratings set forth in the performance evaluation.

        GSC also alleges that the Navy's final performance evaluation is arbitrary and
capricious because it is based on erroneous factual conclusions regarding its performance
under the contract (app. mot. at 1, 3, 5, 11), which necessarily requires an examination of the
details of GSC's performance that underlie the Navy's adverse ratings. See Todd Constr.,
656 F .3d at 1316-17 (complaint challenging negative performance evaluation which alleged
that many, but not all, substantial delays were excusable failed to state a claim upon which
relief could be granted); Versar, Inc., ASBCA No. 56857 et al., 12-1 BCA ~ 35,025
at 172,128, recon. denied, 12-2 BCA ~ 35,126 (denying claim challenging negative
performance evaluation where contractor's allegations of defective specifications,
constructive changes, and breaches of the duties of good faith and fair dealing and to
cooperate were unmeritorious). In short, the adequacy and propriety of the evaluation is
inextricably intertwined with the plethora of genuine factual issues presented in the related
companion appeals. The motion cannot be granted. Cf, e.g., The Pub. Warehousing Co.,
ASBCA No. 57510, 13 BCA ~ 35,314 at 173,363 (citing Adickes v. S. H Kress & Co.,
398 U.S. 144, 160 (1970)).

       In the majority of our appeals requiring extensive factual analysis and often
involving complex issues and voluminous records, summary disposition is generally
inappropriate. Just resolution of disputes involving even ultimately undisputed facts
often necessitates fuller development of the evidentiary record in order that facts may be
properly organized and analyzed in their proper context and chronology. 1 See, e.g.,
Askew v. Hargrave, 401U.S.476, 478-79 (1971); International Raw Materials, Ltd. v.
Stauffer Chemical Co., 978 F.2d 1318, 1333 (3d Cir. 1992), cert. denied, 507 U.S. 988
(1993); Eby v. Reb Realty, Inc., 495 F.2d 646, 648-49 (9th Cir. 1974); Miller v. General
Outdoor Advertising Co., 337 F.2d 944, 948 (2d Cir. 1964) (summary judgment "too

1
    Moreover, to the extent that the parties in the case of cross-motions are convinced that
        summary resolution is appropriate, they have the option of submitting their cases
        for decision on the record pursuant to Rule 11.

                                               3
blunt a weapon" where complex factual and legal issues are present); S.J. Groves & Sons
Co. v. Ohio Turnpike Commission, 315 F.2d 235, 237-38 (6th Cir. 1963), cert. denied,
375 U.S. 824 (1963); Palmer v. Chamberlin, 191 F.2d 532, 540 (5th Cir. 1951).
Conflicting interpretations and inferences that can be drawn from even undisputed facts
are also generally best evaluated on a complete record. See, e.g., Lighting Fixture &
Electric Supply Co. v. Continental Insurance Co., 420 F.2d 1211, 1213 (5th Cir. 1969);
S.J. Groves & Sons, 315 F.2d at 237-38; Chenette v. Trustees ofIowa College, 431 F.2d
49, 53 (8th Cir. 1970); United States v. Lange, 466 F.2d 1021, 1026 (9th Cir. 1972); see
also Virgil v. Time, Inc., 527 F.2d 1122, 1131 (9th Cir. 1975), cert. denied, 425 U.S. 998
(1976) (noting the importance of the exercise of judicial discretion in denying summary
judgment motion pending development of complete record); Lind v. UPS, Inc., 254 F .3d
1281, 1284 (11th Cir. 2001).

       The motion is denied.

      Dated: 18 August 2014

                                                 Administrative Judge
                                                 Armed Services Board
                                                 of Contract Appeals

I concur                                         I concur

~~~
Administrative Judge
                                                RICHARD SHACKLEFORD
                                                Administrative Judge
Acting Chairman                                 Vice Chairman
Armed Services Board                            Armed Services Board
of Contract Appeals                             of Contract Appeals

                                            4
        I certify that the foregoing is a true copy of the Opinion and Decision of the
.A.rrned Services Board of Contract .A.ppeals in .A.SBC.A. No. 58747, .A.ppeal of GSC
Construction, Inc., rendered in conformance with the Board's Charter.

       Dated:

                                                  JEFFREY D. GARDIN
                                                  R..ecorder, .A.rrned Services
                                                  Board of Contract .A.ppeals

                                              5