Court Opinion

ID: 2649564
Source: CourtListenerOpinion
Date Created: 2014-01-16 18:26:14.237101+00
Date Added: 2024-06-11T12:55:41.711540
License: Public Domain

FOURTH DIVISION
                                                                       December 19, 2013

2013 IL App (1st) 112802

Nos. 1-11-2802 and 1-12-0432, Consolidated

GK DEVELOPMENT, INC., an Illinois Corporation, and )                   Appeal from the
COLLEGE SQUARE MALL DEVELOPMENT, LLC, a )                              Circuit Court of
Delaware Limited Liability Company,                )                   Cook County.
                                                   )
             Plaintiffs-Appellees,                 )
                                                   )
v.                                                 )                   Nos. 06 CH 3427 and
                                                   )                        06 CH 3586, Cons.
IOWA MALLS FINANCING CORPORATION, a                )
Delaware Corporation, COLLEGE SQUARE MALL          )
ASSOCIATES, LLC, a Delaware Limited Liability      )
Company, and CHICAGO TITLE AND TRUST               )
COMPANY, an Illinois Corporation,                  )                   Honorable
                                                   )                   Carolyn Quinn,
             Defendants-Appellants.                )                   Judge Presiding.

       PRESIDING JUSTICE HOWSE delivered the judgment of the court, with opinion.
       Justices Fitzgerald Smith and Lavin concurred in the judgment and opinion.

                                             OPINION

¶1     The issue presented in this case is whether a provision in a contract for the sale of four

shopping centers, which required that $4.3 million of the purchase price be held in escrow from

the seller's proceeds then be paid to the seller only if certain conditions are timely met, is

enforceable as a liquidated damages clause or is unenforceable as a penalty.

¶2     In a $117 million transaction, plaintiffs GK Development, Inc., and College Square Mall

Development, LLC (collectively Buyer), purchased from defendants Iowa Malls Financing

Corporation and College Square Mall Associates, LLC (collectively Seller), four shopping

centers in eastern Iowa, including College Square Mall (Mall). Prior to the sale, Mall tenant Hy-
1-11-2802)
1-12-0432)Cons.

Vee Food Stores, Inc. (Hy-Vee), was in the process of expanding its grocery store (Hy-Vee

Expansion) into the space that had been vacated by Wal-Mart after Wal-Mart decided not to

renew its lease. Because the parties did not expect the Hy-Vee Expansion to be completed by the

time of the closing, Buyer and Seller negotiated to hold $4.3 million of the purchase price in

escrow (Hy-Vee Holdback), which represented the present value of the leasehold with regard to

the forthcoming Hy-Vee Expansion.

¶3     An amendment to the purchase agreement directed defendant Chicago Title and Trust

Company (the Escrowee) to release the Hy-Vee Holdback to Seller only after and if all the

following events occurred: (1) a new Hy-Vee lease was executed by August 31, 2005; (2) the

new Hy-Vee leasehold was delivered by Buyer and accepted by Hy-Vee before October 31, 2005;

and (3) Hy-Vee obtained all permits and other governmental approvals necessary to complete the

Hy-Vee Expansion prior to October 31, 2005. Hy-Vee did not obtain the necessary permits

before October 31, 2005; however, both parties demanded that the Escrowee disperse the Hy-Vee

Holdback in their favor. Both Buyer and Seller subsequently filed separate lawsuits seeking a

declaratory judgment regarding their entitlement to the Hy-Vee Holdback, and the two lawsuits

were consolidated into the instant action. Following a three-week bench trial, the trial court

found that the parties intended a “drop-dead deadline” of October 31, 2005 for plan and permit

approval, and that Buyer was entitled to the Hy-Vee Holdback as liquidated damages for a breach

of contract. The trial court also granted Seller’s posttrial motion to “Stay Enforcement of the

Circuit Court’s order and Judgment and Not Apply Post-Judgment Interest During Appeal.”

Both parties appealed, and those appeals were consolidated.

                                                 2
1-11-2802)
1-12-0432)Cons.

¶4      Within Seller's appeal (appeal No. 1-11-2802), Seller argues: (1) that the Hy-Vee

Holdback is not a valid liquidated damages provision because it amounts to an unenforceable

penalty clause; (2) that the trial court erred in finding the parties’ agreement ambiguous; (3) that

the trial court’s interpretation of the parties’ contract violates Illinois rules of contract

construction; and (4) that the trial court erred as a matter of law in failing to award attorney fees

to Seller. In response, Buyer claims: (1) that the Hy-Vee Holdback is a valid and enforceable

liquidated damages provision as construed by the trial court; (2) that the trial court’s finding that

the contract terms were ambiguous and required extrinsic evidence to interpret the parties intent

was reasonable; (3) that Seller forfeited several of its arguments concerning the trial court’s

contract interpretation; and (4) that Seller is not entitled to attorney fees. Within Buyer's appeal

(appeal No. 1-12-0432), Buyer argues that the trial court’s order denying Buyer post-judgment

interest must be reversed. For the following reasons, we reverse the trial court's order directing

the $4.3 million be returned to the Buyer because we find that the contract provision under

review is unenforceable as a penalty clause.

                                        ¶ 5 I. BACKGROUND

¶6      In 2004, Seller owned four shopping malls in eastern Iowa, which included College

Square Mall in Cedar Falls, Iowa. Wal-Mart and Hy-Vee were among the larger “anchor” stores

in the Mall. The Wal-Mart occupied 160,128 square feet of space, while the Hy-Vee occupied a

smaller, 59,860-square-foot building adjacent to it. Hy-Vee’s original lease began in 1976 and

was due to expire on December 31, 2010, subject to three, five-year renewal options. The lease

provided that Hy-Vee pay a $26,166.67 monthly rent ($314,000 annum, or $5.25 per square foot)

                                                    3
1-11-2802)
1-12-0432)Cons.

from January 1, 2006, through December 31, 2010. In addition to this base rent, Hy-Vee paid a

pro rata share of real estate taxes and common area maintenance (CAM).

                                 ¶ 7 A. The Purchase Agreement

¶8     Prior to trial, the parties stipulated to the following in a joint statement of agreed facts.

¶9     In June 2004, Seller began marketing the Mall for sale and issued an offering

memorandum, which opined that Hy-Vee would relocate to a larger leasehold of 75,000 square

feet in Wal-Mart’s former space. The Hy-Vee Expansion would increase its rented square

footage by 15,000 square feet at a cost of $6 per square foot, and the former Hy-Vee space would

be divided to accommodate “two new big box anchors.” The memorandum contemplated that

Hy-Vee would execute a new 60-month lease by March 2005. Buyer then entered into

discussions with Seller to purchase the Mall.

¶ 10   In July 2004, Buyer executed a letter of intent to purchase the Mall, as well as the three

other Iowa malls, for $117 million. On September 17, 2004, Buyer and Seller entered into a real

estate sales contract (Purchase Agreement) to purchase the four malls, and set a closing date of

December 17, 2004.

¶ 11   On October 12, 2004, Hy-Vee executed a letter of intent (Letter of Intent) to open a “first

class high quality Hy-Vee retail grocery store,” which is described as a “21st century prototype,”

in the space formerly occupied by Wal-Mart. The Letter of Intent contemplated that Hy-Vee

would lease 78,337 square feet for a minimum term of 20 years, followed by five, five-year

renewal options. The initial base rent would be $7 per square foot and would incrementally rise

to $9.35 per square foot beyond the initial 20-year term. In addition to the base rent, Hy-Vee

                                                  4
1-11-2802)
1-12-0432)Cons.

would pay a certain pro rata share of the Mall’s real estate taxes and CAM. The parties agreed

that the proposed Hy-Vee lease, which would increase the fair market value of the Mall, would

not be executed prior to the closing on the sale of the Mall. Seller and Hy-Vee agreed that Hy-

Vee would require 270 days to extensively remodel the new leasehold. The Letter of Intent

indicated that Hy-Vee’s “possession date” would occur upon: (1) execution of the lease; (2)

receipt of certain government approvals; and (3) delivery of the space from Buyer.

¶ 12    On October 26, 2004, Buyer’s primary negotiator, Thomas Rogers, sent a letter1 to

Seller’s broker, George Good of CB Richard Ellis, that outlined certain issues of concern. One

issue of concern was the economic impact of the Hy-Vee Expansion because it was not expected

that Hy-Vee would sign a new lease before the December 2004 closing. To calculate the present

value of the Hy-Vee Expansion, Rogers determined that the new lease would generate a future

incremental income of $430,000 per year. He next calculated that, based on a 10% capitalization

rate, the present value of the 20-year Hy-Vee Expansion lease was $4.3 million. To resolve the

uncertainty of the new lease’s impact on the $117 million sale, Rogers suggested that the $4.3

million be held back in escrow until: (1) the new lease was signed; (2) the supermarket was open

for business: and (3) the leasehold was lien free.

                                    ¶ 13 B. The Third Amendment

        1
            Rogers’ letter was not included in the joint statement of facts; however, it was admitted
into evidence at trial.

                                                    5
1-11-2802)
1-12-0432)Cons.

¶ 14   On November 10, 2004, Buyer and Seller entered into the "Third Amendment to Real

Estate Sale Contract" (Third Amendment) to memorialize the parties' holdback agreement.

Accordingly, the Third Amendment provided that $4.3 million of the purchase price would be

held in escrow and released to Seller when and if: (1) Hy-Vee executes a new lease by August

31, 2005; (2) Buyer delivers and Hy-Vee accepts the new leasehold by October 31, 2005; and (3)

Hy-Vee obtains, by October 31, 2005, all permits and other governmental approvals necessary to

complete the expansion. Specifically, the Third Amendment provides in relevant part:

              “With respect to [the Mall], [the Buyer] and the Seller of said

              Property agree that at Closing they will enter into a Four Million

              Three Hundred Thousand and 00/100 Dollar ($4,300,000.00)

              holdback agreement from the purchase price of said Property ***.

              The holdback amount shall not be released until all of the

              following are satisfied: (1) execution of the lease with Hy Vee, Inc.

              on terms in accordance with Letter of Intent, dated October 12,

              2004, attached hereto as Exhibit C, and in a form that is

              commercially reasonable; (2) delivery of the premises to [Hy-Vee]

              in the condition required *** as specified in the lease; and (3)

              acceptance by [Hy-Vee] of the premises and the obtaining by

              [them] of all permits and other governmental approvals necessary

              to complete the tenant’s work. Should the lease not be executed by

              August 31, 2005, or all of the other conditions not be satisfied by

                                                6
1-11-2802)
1-12-0432)Cons.

               October 31, 2005, the holdback amount shall not be released to the

               Seller, but it shall be forfeited and delivered to [the Buyer].”

¶ 15   Thomas Rogers, Buyer’s primary negotiator, testified that he negotiated the $4.3 million

figure with Seller’s primary negotiator, Michael Fontana. Furthermore, Rogers testified that the

October 31, 2005 deadline was proposed by Seller, which was corroborated by the testimony of

Gerry Curciarello and Patrick O’Leary, co-managing partners of Seller. Curciarello also testified

at trial that the $4.3 million figure and the October deadline were the products of an arm’s-length

negotiation between Buyer and Seller, and that, at the time of the negotiations, he felt that the

deadline was sufficiently distant to allow Seller to meet all of its obligations.

                         ¶ 16 C. The Deed and Money Escrow Agreement

¶ 17   Prior to closing, on December 15, 2004, Buyer and Seller entered into a "Deed and

Money Escrow Agreement" (DME), as required by the Third Amendment. The DME instructed

the Escrowee to release the Hy-Vee Holdback upon the completion of the following events: (1)

execution of a new commercially reasonable lease in conformity with the Letter of Intent; (2)

delivery of the space to Hy-Vee; (3) acceptance of the space by Hy-Vee; and (4) Hy-Vee’s receipt

of all permits and other governmental approvals necessary for Hy-Vee to complete the

expansion. Specifically, section VII of the DME, titled “Hy-Vee Holdback,” provides as follows:

               “At any time after the Closing Date that [the Seller] shall advise

               [the Escrowee], in writing, and under oath, that (a) a lease in a

               commercially reasonable form has been signed by Hy-Vee, Inc.

               ('Hy-Vee') for the space previously occupied at [the Mall] by Wal-

                                                  7
1-11-2802)
1-12-0432)Cons.

               Mart ('the Hy-Vee Space') substantially in accordance with the

               Letter of Intent dated October 12, 2004, (b) that the Hy-Vee Space

               has been delivered to Hy-Vee in the condition required by the

               terms of such lease, © that the tenant [Hy-Vee] thereunder has

               accepted the Hy-Vee Space and (d) that such tenant has obtained

               all government approvals and permits necessary for it to complete

               its work, then [the Escrowee] shall advise [the Buyer] in writing of

               such demand for payment and, unless [the Escrowee] receive

               objection in writing within five (5) days, the Hy-Vee Holdback

               shall be made to [the Seller]. If said objection is timely made, [the

               Escrowee is] to continue to hold the Hy-Vee Holdback subject to

               the joint direction of the parties or order of court.”

Section VII further provides the following deadlines for these four events to occur:

               “In the event that the Seller is unable to deliver such a lease signed

               by Hy-Vee on or before August 31, 2005, or in the event the

               conditions of Subscriptions (b), © and (d) are not satisfied on or

               before October 31, 2005, without default of [the Buyer], then, and

               only in such event, the Hy-Vee Holdback shall be paid to [the

               Buyer]; provided, however, if the plans have not been finalized by

               reason of any delay in producing, approving or revising such plans

               (such delay to be determined in accordance with the terms of Hy-

                                                  8
1-11-2802)
1-12-0432)Cons.

               Vee’s lease), then, and in all such events, the October 31, 2005

               date shall be extended by one day for each day of delay in the

               delivery plan approval. If [the Seller] shall notify Escrowee that it

               claims a delay and extension, Escrowee shall retain the Hy-Vee

               Holdback subject to a joint direction of the parties or an order of

               the court.”

Curciarello testified that, at the time the DME was executed, he still believed that the October 31,

2005 deadline was sufficiently distant to allow Seller to complete all of its obligations.

¶ 18    Section VII also provides that Buyer will perform certain parking lot improvements and

that Seller will later reimburse Buyer for the construction costs. If the parking lot improvements

are the sole reason for Hy-Vee not fulfilling its obligations prior to the October 31, 2005

deadline, then Seller will not be determined to have failed to meet the deadline. In such event,

105% of the parking lot construction costs (determined by competitive bidding) will be paid to

Buyer out of the Hy-Vee Holdback, and the remainder of the Hy-Vee Holdback will be released

to Seller.

                                 ¶ 19 D. The New Hy-Vee Lease

¶ 20    Closing took place on December 17, 2004, and Buyer purchased the four Iowa malls for

$117 million, including the Mall, which accounted for $38.5 million of the purchase price. The

Mall was divided into two parcels: parcel 1, which was valued at $33.5 million and included the

entire Mall property except for the Hy-Vee and former Wal-Mart leaseholds, and parcel 2, which

was valued at $5 million and included only the Hy-Vee and former Wal-Mart leaseholds. Of the

                                                  9
1-11-2802)
1-12-0432)Cons.

$5 million paid for parcel 2, $4.3 million was held in escrow pending the requirements laid out in

the Third Amendment and DME.

¶ 21   After closing, Seller engaged Hy-Vee in negotiating a new lease. While the new lease

was being negotiated, Seller contracted and paid for an asbestos abatement in the former Wal-

Mart space, which was completed in June 2005. Hy-Vee signed the new lease (Hy-Vee Lease)

on June 16, 2005. The Hy-Vee Lease provided for 79,750 square feet of the former Wal-Mart

space at a price of $7 per square foot, and contemplated a minimum 20-year term, followed by

five successive five-year options, which would run for a total term of 45 years. The Hy-Vee

Lease provided that the original Hy-Vee store would operate while the new leasehold was

remodeled and that the 20-year term would begin to run on the date of possession, with rent

becoming due on the rent commencement date.

¶ 22   Upon receiving the Hy-Vee Lease, Buyer requested that Hy-Vee make two revisions.

Although Hy-Vee refused to make the suggested revisions, Buyer signed the Hy-Vee Lease on

July 15, 2005.

¶ 23   Section 3(A) of the Hy-Vee Lease provides that Hy-Vee has 75 days following the

execution of the lease, or until September 28, 2005, to submit “detailed plans and specifications

for the Hy-Vee Expansion” to Buyer for approval. Buyer would then have 10 business days to

approve the plans. If Buyer disapproves of the final plans, then Hy-Vee would have until 10

business days thereafter to submit revised plans, followed by an additional 7 business days for

Buyer to approve them. More specifically, section 3(A)(1) provides in relevant part:

                                                10
1-11-2802)
1-12-0432)Cons.

                      “(1)   Plans and Approvals. Landlord [the Buyer] and

              Tenant [Hy-Vee] have reviewed and approved Tenant’s

              preliminary site plan for the Hy-Vee Expansion attached hereto as

              Exhibit B (the 'Site Plan'). On or before the 75th day following the

              date of this lease, Tenant at its expense shall submit to Landlord

              detailed plans and specifications for the Hy-Vee Expansion (the

              'Final Plans and Specifications'), prepared by Tenant for Landlord’s

              approval, which approval Landlord shall not unreasonably

              withhold, condition or delay. *** Landlord shall within ten (10)

              business days after receipt of all of said Final Plans and

              Specifications notify Tenant in writing of its approval or

              disapproval thereof, with any such disapproval to be specifically

              explained. If Landlord does not approve the Final Plans and

              Specifications as initially submitted, Tenant shall within ten (10)

              business days thereafter submit for approval revised Final Plans

              and Specifications addressing any objections. Landlord shall then

              have seven (7) business days after receipt of said revised Final

              Plans and Specifications to approve or disapprove same.”

Also, section 3(A)(1) of Hy-Vee Lease (titled “Plans and Approvals”) provides certain

“Construction Conditions” that must be met. Subsection (a) provides for the mutual agreement

between Buyer and Hy-Vee on final plans and specifications within the time frame set forth in

                                                11
1-11-2802)
1-12-0432)Cons.

section 3(A)(1). Subsection (d) provides that Hy-Vee must promptly submit an application for

building permits, and that it shall obtain those permits and other governmental approvals within

30 days after Buyer’s approval of the final plans and specifications. Subsection (d) also contains

a delay provision, which provides that if Hy-Vee submits permit applications and diligently

pursues obtaining them prior to the deadline, then it could, upon its written request, obtain a 60-

day extension. Specifically, section 3(A)(1) of the Hy-Vee Lease provides the following

construction conditions:

               "The construction of the Hy-Vee Expansion shall be further subject

               to the satisfaction of the following conditions (the 'Construction

               Conditions'):

                       (a) The mutual agreement of Landlord and Tenant to the

               plans and specifications for the Hy-Vee Expansion, as provided

               and within the time parameters set forth in Section 3(A)(1);

                                               ***

                       (d) Tenant agrees to promptly submit an application for

               building permits and shall obtain all such permits and other

               governmental authorizations (the 'Government Approvals')

               required for construction of the Hy-Vee Expansion within thirty

               (30) days after the Landlord’s approval of Tenant’s Final Plans and

               Specifications;; [sic] provided, however, if Tenant timely submits

               such permit applications and diligently pursues obtaining such

                                                 12
1-11-2802)
1-12-0432)Cons.

               permits, upon the written request of Tenant, Tenant may obtain a

               sixty (60) day extension of the Construction Condition set forth in

               this subsection 3(A)(1)(d).”

It is undisputed that Hy-Vee did not make a written request to Buyer for an extension, and that

Buyer did not notify Hy-Vee of any default under the Hy-Vee Lease.

¶ 24   Furthermore, section 3(A)(1) provides that Buyer has 120 days following the execution of

the lease, or until November 13, 2005, to reach an agreement with Hy-Vee on the final plans and

specifications, and if not, then Hy-Vee would have the option to abandon the expansion and

remain on its original lease, while the new Hy-Vee Lease would be rendered void. Section

3(A)(1) further provides in relevant part:

               “Tenant shall provide written notice to Landlord when all of the

               Construction Conditions have been satisfied and/or waived ***. In

               the event that (I) the Construction Condition set forth in

               subparagraph (a) is not satisfied within one hundred and twenty

               (120) days following the date of this Lease; *** or (iv) the

               Construction Condition set forth in subparagraph (d) is not

               satisfied within 30 days after Landlord approves the Tenant’s plans

               and specifications (or 90 days if extended for the additional 60-day

               period as provided above), are not satisfied and/or waived by

               Tenant within (w) the 120-day period as to clause (I) set forth

               above, *** and (z) the 30-day period (or 90-day period, if extended

                                                13
1-11-2802)
1-12-0432)Cons.

               the additional 60-day period) as to clause (iv) set forth above,

               Tenant may, as Tenant’s sole and exclusive remedy, elect to

               terminate this lease by written notice delivered to Landlord on or

               before the expiration of (w) the 120-day period as to clause (I) set

               forth above, *** and (z) the 30-day period (or 90-day period, if

               extended the additional 60-day period) as to clause (iv) set forth

               above and, in such case, the Old Lease shall remain in full force

               and effect. If Tenant does not give such termination notice ***,

               this lease shall remain in full force and effect and the Old Lease

               shall be deemed to be terminated as provided in Section 52

               hereof.”

Hy-Vee submitted its final plans and specifications to Buyer on the September 28, 2005 deadline.

Ten business days later, Buyer disapproved the plans and requested Hy-Vee to make certain

revisions. On October 31, 2005, or 13 business days later, Hy-Vee submitted its revised final

plans and specifications. October 31, 2005 was also the deadline set forth in the Third

Amendment and the DME for Hy-Vee to obtain building permits and other government

approvals, and Hy-Vee applied to the Cedar Falls building department for a construction permit

and other necessary approvals on that day. Six business days later, on November 8, 2005, Buyer

approved Hy-Vee’s revised plans.

                                                14
1-11-2802)
1-12-0432)Cons.

¶ 25   On November 2, 2005, Seller sent to Buyer a letter2 proposing to extend the Third

Amendment’s October 31, 2005 deadline to January 31, 2006. In addition to the extended

deadline, Seller proposed that the Hy-Vee Holdback be released to Seller, less the cost Buyer

spent on the construction of Hy-Vee’s new parking lot. Buyer responded on November 16, 2005

with a counter proposal that contemplated an extended deadline in exchange for Seller paying

Buyer for rent that would have been paid had the original deadline been met. According to

Buyer, the rent that would have been paid was approximately $47,000 per month plus a pro rata

share of real estate taxes and CAM. Additionally, Buyer proposed that if the new deadline were

not met, Buyer would receive $100,000 per month from the Hy-Vee Holdback in lieu of rent

payments. The negotiations did not advance past Buyer’s counteroffer, and the October 31, 2005

deadline was never extended.

¶ 26   On January 6, 2006, Buyer sent a letter to the Escrowee demanding that it release the

entire $4.3 million Hy-Vee Holdback to Buyer because Seller did not meet the October 31, 2005

deadline. Three days later, Seller sent the Escrowee a letter objecting to the release of the Hy-

Vee Holdback to Buyer, requesting that the Escrowee retain the Holdback subject to joint

direction of the parties or the receipt of a court order. Later that day, Buyer sent another letter to

the Escrowee stating that it agreed that the Escrowee should retain the Hy-Vee Holdback until

the dispute was resolved. On February 9, 2006, Seller sent another letter to the Escrowee

demanding that it release the Hy-Vee Holdback to Seller because all of the conditions required

       2
         Though neither Seller’s proposal nor Buyer’s counterproposal was included in the joint
statement of facts, both were admitted into evidence at trial.

                                                  15
1-11-2802)
1-12-0432)Cons.

for release of the funds had been met, expect for the completion of the parking lot improvements.

Seller demanded that the $200,000 cost of the parking lot construction be deducted from the Hy-

Vee Holdback, and the remaining $4.1 million be released to Seller. On February 10, 2006 and

February 14, 2006, Buyer sent letters to the Escrowee objecting to the release of the Hy-Vee

Holdback, and requesting that the Escrowee continue to retain the Holdback until it received a

joint direction from the parties or a court order.

¶ 27     On January 27, 2006, Hy-Vee obtained a construction permit from the City of Cedar

Falls. Three days later, Buyer delivered the new space, which totaled 80,189 square feet, to Hy-

Vee, and Hy-Vee accepted it and all necessary permits were obtained. Under the terms of the

Lease, Hy-Vee was required to complete the construction on the expansion within the next 330

days. Hy-Vee’s acceptance of the premises also triggered its obligation to begin paying a pro rata

share of the Mall’s real estate taxes and CAM, in addition to its share of the existing Hy-Vee

leasehold. Hy-Vee would then begin paying a minimum fixed base rent of $46,521 per month

within the next 270 days, or when the new Hy-Vee supermarket opened, whichever occurred

first.

                                   ¶ 28 E. The Instant Litigation

¶ 29     On February 17, 2006, Buyer filed an action in the chancery division of the circuit court

of Cook County against Seller and the Escrowee seeking declaratory judgment and specific

performance, claiming that it was entitled to the $4.3 million Hy-Vee Holdback as liquidated

damages for Seller’s failure to fulfill its contractual obligations prior to the October 31, 2005

deadline (case No. 06 CH 3427).

                                                     16
1-11-2802)
1-12-0432)Cons.

¶ 30   Seller also filed a suit in the chancery division on February 22, 2006 against Buyer

seeking a declaratory judgment that it was entitled to the release of the entire Hy-Vee Holdback

(case No. 06 CH 3586). Seller claimed that Hy-Vee’s failure to obtain the necessary building

permits prior to October 31, 2005 did not amount to a contractual violation because the

“provided, however” clause of the Hy-Vee Lease extended the deadline to February 12, 2006.

Seller also claimed that Buyer breached the DME by claiming that Seller had not fulfilled its

requirements.

¶ 31   The circuit court subsequently consolidated both lawsuits.

¶ 32   Buyer also filed a separate lawsuit (case No. 06 CH 26662) against Seller seeking the

recovery of $530,294.86 from the Hy-Vee Holdback for the costs that it expended on the Hy-Vee

parking lot construction.

¶ 33   While the litigation was pending, on November 16, 2006, Hy-Vee opened its new

supermarket in the former Wal-Mart leasehold, and has since been making payments as required

under the new Hy-Vee lease.

¶ 34   Seller moved for summary judgment on December 4, 2008, arguing that the clear and

unambiguous language of the Hy-Vee Lease extended the deadline for Hy-Vee to obtain

government approvals from October 31, 2005 to February 2006. In response, Buyer argued that

only a delay by Buyer in the delivery of plan approvals could extend the deadline. The trial court

denied Seller’s motion on April 9, 2009, finding that the provisions of the Third Amendment,

DME, and Hy-Vee Lease, when read together, were “ambiguous as to whether the governmental

approvals and authorizations [fell] within the delay provision of Section VII of the DME”

                                               17
1-11-2802)
1-12-0432)Cons.

because the terms “plans” and “plan approval” were not clearly defined or consistently used

throughout the documents. The trial court stated that “it is not clear whether the October 31,

2005 deadline would be extended only for delays in approving the Plans and Specifications or for

delays in approving the Plans and Specifications and obtaining the Government Approvals.” The

case then proceeded to trial for a hearing of extrinsic evidence to resolve this contractual

ambiguity.

¶ 35   At trial, the circuit court heard testimony from: Garo Khalamian, president and owner of

GK Development, Inc.; David Sullivan, senior vice-president of development for Buyer; Michael

Fontana, Seller’s senior property accountant; Gary Curciarello, co-managing partner of Seller;

and Patrick O’Leary, co-managing partner of Seller along with Curciarello. It also reviewed

evidentiary deposition testimony from: Thomas Rogers, Buyer’s primary negotiator; and David

Bailey, assistant vice president, real estate, for Hy-Vee. In addition, the trial court considered the

parties’ documentary evidence, such as the letters and emails exchanged between the witnesses.

¶ 36   At trial, the parties focused a great deal of time on the issue of whether the parties had

intended a firm deadline of October 31, 2005 for Hy-Vee to obtain governmental approvals, or

whether the date was an aspirational target for the Hy-Vee Expansion. O’Leary, Curciarello, and

Fontana each testified that the October 31, 2005 deadline was a “target” or “place holder” date

that was not intended to be rigidly enforced. On cross-examination, however, Curciarello

admitted that in his prior deposition testimony he testified that the purpose of a October 27, 2005

telephone conference involving himself, Garo, and Fontana was to extend the October 31

deadline. Buyer also impeached Fontana’s testimony with a January 10, 2005 email sent to

                                                 18
1-11-2802)
1-12-0432)Cons.

O’Leary and Curciarello in which Fontana wrote that “Our [the Seller’s] contract with GK [the

Buyer] requires us to deliver the space to Hy-Vee with plans approved and permits issued by

October 31, 2005, or forfeit the money held back.” Fontana wrote in an email that as long as the

Hy-Vee Lease is executed by April 1, 2005, then it would be likely that the space would be

delivered in time and “the seller will get the money held in escrow.” Moreover, Fontana also

wrote in the email that Seller was protected by a clause that provides that “delays in the Hy-Vee

planning/permitting process beyond the time periods set out in the lease that are caused by GK or

Hy-Vee do not count against the seller.” Buyer further impeached Fontana’s testimony with a

March 2, 2005 email in which Fontana wrote to Curciarello that Seller would be “in jeopardy” if

the Hy-Vee Lease were not executed by April 12, 2005, because “the contract with GK requires

*** the space to be delivered with all delivery conditions met by October 31.”

¶ 37   Following the three-week bench trial, in additional to the facts stipulated to by the parties,

the trial court made additional findings of fact, which included:

                       "35. Seller negotiated the terms of the New Hy Vee Lease.

               Buyer was permitted to suggest Lease contents and did so, but

               Buyer had no right to dictate lease terms. None of the lease

               changes suggested by buyer concerned deadlines for submissions

               or approval of plans or permits.

                       36. If Buyer had refused top sign a lease that Seller deemed

               'commercially reasonable,' Seller would have sued Buyer for

               breach of contract.

                                                  19
1-11-2802)
1-12-0432)Cons.

                    37. The New Hy Vee Lease contained time periods

             triggering obligations between landlord and tenant, but did not

             contain a terminal date for obtaining governmental permits.

                    38. Seller never told Hy Vee that the deadlines calculated

             in the New Hy Vee Lease needed to be shortened to comply with

             the October 31, 2005 deadline.

                    39. Buyer never indicated it was concerned about the

             schedule set forth in the Hy Vee Lease.

                    40. At the time the parties executed the Third Amendment

             and DME, Seller and Buyer believed that the New Hy Vee Lease

             would be executed prior to August 31, 2005, and that the tenant

             could obtain pain approval and necessary permits by October 31,

             2005. Seller believed the lease would be negotiated no later than

             March, 2005. As late as March, 2005, Fontana believed a lease

             could be executed in April followed by approval and permitted

             plans by October 31, 2005. As of July 15, 2005, it was still

             possible that the October 31, 2005 deadline could be met.

                    41. When Buyer and Seller negotiated the Third

             Amendment and DME, they intended October 31, 2005, to be the

             deadline for Hy Vee to obtain plan approval and government

             permits.

                                              20
1-11-2802)
1-12-0432)Cons.

                    42. The purpose of an October 27, 2005, telephone

             conference involving Garo, Fontana, Curciarello, Sullivan and

             Rogers was in part to negotiate an extension of the October 31,

             2005, deadline set forth in the contract documents. At Buyer's

             suggestion, Seller drafted a proposed extension of the October 31,

             2005 deadline to January 31, 2006. Buyer did not accept this

             proposed amendment.

                    43. The difference between the existing Hy Vee lease and

             the new Hy Vee lease was approximately $430,000.00 in additional

             annual income to the landlord (Buyer). The Hy Vee Holdback

             amount of $4,300,000.00 was a term negotiated by the parties and

             fairly represented the incremental value of the Hy Vee Lease.

                    44. By the October 21, 2004, LOI, Hy Vee proposed

             opening a 'first class high quality Hy Vee retail grocery store', a

             '21st century prototype' in the 78,000 square feet space previously

             occupied by Wal Mart.

                    45. Hy Vee was one of the anchor stores at College Square

             Mall. Its existing space could be modified to house two new,

             additional anchor stores. An expanded Hy Vee was marketed as a

             draw for other retailers to the mall. The mall housed multiple

             tenants and could accommodate right 'anchor spaces.' "

                                               21
1-11-2802)
1-12-0432)Cons.

¶ 38    Based on the stipulated facts and the facts laid out above, the trial court found that the

parties “intended October 31, 2005, to serve as the deadline for plan and permit approval,” and

that Seller was in breach of contract because Hy-Vee did not obtain the necessary permits prior to

October 31, 2005. The trial court further found that the Hy-Vee Holdback constituted a valid and

enforceable liquidated damages clause, and it awarded the entire $4.3 million Hy-Vee Holdback

to Buyer. The trial court also dismissed the related lawsuit in case No. 06 CH 26662 as moot

because any damages owed to Buyer for the parking lot construction would have been paid out of

the Hy-Vee Holdback.

¶ 39    Seller appeals case nos. 06 CH 3427 and 06 CH 3586, consolidated (appeal No. 1-11-

2802), claiming: (1) that the Hy-Vee Holdback is not a valid liquidated damages provision; (2)

that the trial court erred in finding the parties’ agreement ambiguous; (3) that the trial court’s

interpretation of the parties’ contract violates Illinois rules of contract construction; and (4) that

the trial court erred as a matter of law in failing to award attorney fees to Seller. In response,

Buyer claims: (1) that the Hy-Vee Holdback is a valid and enforceable liquidated damages

provision; (2) that the trial court’s finding that the contract terms were ambiguous and required

extrinsic evidence to interpret the parties' intent was reasonable; (3) that Seller did not forfeit

several of its arguments concerning the trial court’s contract interpretation; and (4) that Seller is

not entitled to attorney fees.

¶ 40    The trial court later granted Seller’s posttrial motion to stay the enforcement of its

judgment and ordered that post-judgment interest would not apply during appeal. Buyer

appealed case Nos. 06 CH 3427 and 06 CH 3586, consolidated (appeal No. 1-12-0432), claiming

                                                  22
1-11-2802)
1-12-0432)Cons.

that the trial court deprived Buyer of its statutory right to post-judgment interest. We

subsequently consolidated the separate appeals.

                                         ¶ 41 II. ANALYSIS

¶ 42    There are two consolidated appeals before this court. First, Seller appeals the trial court’s

judgment in favor of Buyer, claiming: (1) that the Hy-Vee Holdback is not a valid liquidated

damages provision because it amounted to an unenforceable penalty; (2) that the trial court erred

in finding the parties’ agreement ambiguous; (3) that the trial court’s interpretation of the parties’

contract violates Illinois rules of contract interpretation; and (4) that the trial court erred as a

matter of law in failing to award attorney fees to Seller. In response, Buyer claims: (1) that the

Hy-Vee Holdback is a valid and enforceable liquidated damages provision; (2) that the trial

court’s finding that the contract terms were ambiguous and required extrinsic evidence to

interpret the parties' intent was reasonable; (3) that Seller forfeited several of its arguments

concerning the trial court’s contract construction; and (4) that Seller is not entitled to attorney

fees. Second, Buyer appeals the trial court’s order denying it post judgment interest, claiming

that the trial court deprived Buyer of its statutory right. For the following reasons, we reverse the

trial court's finding that the liquidated damages clause was enforceable because the clause: (1)

failed to satisfy the Jameson factors, (2) resulted in a windfall for Buyer, and (3) functions as a

penalty for Seller's 91-day nonperformance.

                                        ¶ 43 A. Seller’s Appeal

¶ 44    Whether a contractual provision for damages is a valid liquidated damages provision or is

an unenforceable penalty clause is a question of law that is reviewed de novo. Penske Truck

                                                   23
1-11-2802)
1-12-0432)Cons.

Leasing Co., L.P. v. Chemetco, Inc., 311 Ill. App. 3d 447, 454 (2000). De novo consideration

means we perform the same analysis that a trial judge would perform. Khan v. BDO Seidman,

LLP, 408 Ill. App. 3d 564, 578 (2011).

¶ 45   Buyer argues in its brief that the appropriate standard of review in determining the

validity of the liquidated damages clause would be an abuse-of-discretion standard because the

trial court made several findings of fact by concluding that the liquidated damages clause was

enforceable. However, at the oral argument of the case, Buyer conceded that the appropriate

standard of review in determining this issue would be de novo.

¶ 46   The central issue in Seller’s appeal is whether the Hy-Vee Holdback is a valid and

enforceable liquidated damages provision. Seller claims that public policy dictates that the Hy-

Vee Holdback provision is an unenforceable penalty because it confers a windfall award to the

non breaching party, and it does not specify damages for a specific breach. Buyer responds that

the provision is not a penalty because Illinois courts have previously upheld liquidated damages

clauses for delayed performance, even when the non-breaching party has suffered little or no

actual damages. For the following reasons, we find that the Hy-Vee Holdback is an

unenforceable liquidated damages provision.

¶ 47   When interpreting contract provisions that specify damages, Illinois courts draw a

distinction between liquidated damages, which are enforceable, and penalties, which are not.

Checkers Eight Ltd. Partnership v. Hawkins, 241 F.3d 558, 562 (7th Cir. 2001). “The test for

determining whether a liquidated-damages clause is valid as such or is void as a penalty is stated

in section 356 of the Restatement (Second) of Contracts: ‘Damages for breach by either party

                                                24
1-11-2802)
1-12-0432)Cons.

may be liquidated in the agreement but only at an amount that is reasonable in the light of the

anticipated or actual loss caused by the breach and the difficulties of proof of loss. A term fixing

unreasonably large liquidated damages is unenforceable on grounds of public policy as a

penalty.’ ” Penske Truck Leasing Co., 311 Ill. App. 3d at 454 (quoting Restatement (Second) of

Contracts § 356 (1979)). “It is a general rule of contract law that, for reasons of public policy, a

liquidated damages clause that operates as a penalty for nonperformance or as a threat to secure

performance will not be enforced.” Jameson Realty Group v. Kostiner, 351 Ill. App. 3d 416, 423

(2004) (citing Med+Plus Neck & Back Pain Center v. Noffsinger, 311 Ill. App. 3d 853, 860

(2000); and Grossinger Motorcorp, Inc. v. American National Bank & Trust Co., 240 Ill. App. 3d
737, 749 (1992)). In doubtful cases, we are inclined to construe the stipulated sum as a penalty.

Stride v. 120 West Madison Building Corp., 132 Ill. App. 3d 601, 605 (1985) (citing Beuttas v.

Garvey, 270 Ill. App. 310, 318 (1933)). Furthermore, “[t]he purpose of damages is to place the

nonbreaching party in a position that he or she would have been in had the contract been

performed, not to provide the nonbreaching party with a windfall recovery.” Jones v. Hryn

Development, Inc., 334 Ill. App. 3d 413, 418 (2002).

                                    ¶ 48 1. The Jameson Factors

¶ 49   In Illinois, courts will generally find a liquidated damages provision to be valid and

enforceable when the three factors laid out in Jameson are satisfied. As stated in Jameson, the

three elements that must be met in order to validate a liquidated damages clause are: (1) the

parties intended to agree in advance to the settlement of damages that might arise from the

breach; (2) the amount of liquidated damages was reasonable at the time of contracting, bearing

                                                 25
1-11-2802)
1-12-0432)Cons.

some relation to the damages which might be sustained, and (3) actual damages would be

uncertain in amount and difficult to prove. Jameson, 351 Ill. App. 3d at 423. Of note, all three

requirements must be met in order to enforce a liquidated damages clause. Here, the Hy-Vee

Holdback does not meet the first two requirements of the Jameson requirements. As such, the

clause is not a valid and enforceable liquidated damages clause.

 ¶ 50 a. The Parties Did Not Agree in Advance That the $4.3 Million Would Be Damages for a
                                 Delay in Obtaining Permits.

¶ 51   The first factor of the Jameson test that must be met in order to validate a liquidated

damages clause is that the parties intended to agree in advance to the settlement of damages that

might arise from the breach. Jameson, 351 Ill. App. 3d at 423. Here, there is no evidence to

suggest that the parties even considered what appropriate damages would be in the event of a

minor delay in obtaining permits. Rather, the evidence shows that the parties considered the

damages in light of a complete failure of the Hy-Vee Lease to come to fruition and, accordingly,

estimated the damages as the present-day value of the entire 20-year lease, or the equivalent of

$4.3 million. Because there is no evidence that the parties contemplated damages for a minor

delay in obtaining permits at the time of creating the liquidated damages clause, we cannot say

that the parties agreed in advance that $4.3 million would represent the damages for any breach,

including a delay of 91 days in obtaining permits.

¶ 52   While we realize that the trial court found that the first prong of Jameson had been met,

we find that the trial court improperly interpreted that prong. The trial court concluded that the

first prong was met because "the insertion and amount of the liquidated damages clause was

                                                 26
1-11-2802)
1-12-0432)Cons.

intentional and negotiated through an arm's-length transaction." While we don't disagree with

these facts as stated by the trial court, we find that such facts do not satisfy the first prong of

Jameson, which requires a showing that the parties intended to agree in advance to the settlement

of damages that might arise from the breach. Jameson, 351 Ill. App. 3d at 423. The mere

negotiation and insertion of the liquidated damages clause does not show that the parties intended

to agree in advance that $4.3 million would serve as liquidated damages for a 91-day delay (or

any delay) in obtaining permits, while leaving the entire value of the 20-year lease still intact.

Therefore, the Hy-Vee Holdback did not satisfy the first prong of the Jameson test and, as a

result, it cannot be enforced as a valid liquidated damages provision.

 ¶ 53 b. The Amount of Liquidated Damages Bore No Relation to the Anticipated Damages of a
                                   Delay in Performance.

¶ 54    Even though failing to satisfy the first prong would be sufficient to find the Hy-Vee

Holdback unenforceable, we find that the second prong was also not satisfied here. The second

Jameson element that must be met in order to enforce a liquidated damages clause is that the

amount of the liquidated damages was reasonable at the time of contracting, bearing some

relation to the damages that might be sustained. Jameson, 351 Ill. App. 3d at 423. Here, the

parties negotiated a $4.3 million holdback, which represented the entire, present-day value of the

20-year lease, in the event that the lease did not go through. In coming to this number, the parties

calculated that Buyer would lose $430,000 each year in rent if the Hy-Vee Expansion lease did

not go through. Thus, while the $4.3 million in liquidated damages might have been reasonable

in the event that the Hy-Vee lease never occurred, it was not reasonable for a 91-day delay in

                                                   27
1-11-2802)
1-12-0432)Cons.

securing government permits. The holdback amount of $4.3 million simply does not bear any

relation to the damages sustained for a 91-day delay in securing permits and, therefore, was not a

reasonable prediction of damages. See Dallas v. Chicago Teachers Union, 408 Ill. App. 3d 420,

425 (2011) (parties not required to make the best estimation of damages, but must make one that

is reasonable).

¶ 55   In fact, Buyer concedes in two places that $4.3 million is not an estimate of damages for a

91-day delay in obtaining permits. First, in coming to the $4.3 million figure, the parties agreed

that the damages in yearly lost rent would be $430,000 per year. Thus, it cannot be said that a

91-day delay, which makes up a small fraction of a year, could reasonably result in $4.3 million

of potential damages. Second, in its November 16 proposal, Buyer offered to extend the October

31, 2005 deadline in exchange for, among other things, paying the monthly rent it would lose as a

result of the delay, which it estimated to be $47,000 per month plus a pro rata share of real estate

taxes and CAM. Even if we multiply this monthly rate by three to equal the 91-day delay, the

total is no where near $4.3 million. Again, this shows that $4.3 million had no relation

whatsoever to the damages that might result from a 91-day delay in obtaining permits. As such,

it is clear that the $4.3 million was not a reasonable estimate of damage for a 91-day delay in

obtaining permits and, accordingly, Buyer cannot establish the second prong of the Jameson test.

Given that all three factors must be met in order to validate a liquidated damages clause, we find

that the Hy-Vee Holdback was not a valid and enforceable liquidated damages provision.

          ¶ 56 2. The Hy-Vee Holdback Amounted to a Windfall Recovery for Buyer.

¶ 57   Our courts have invalidated liquidated damages clauses where they amount to a windfall

                                                 28
1-11-2802)
1-12-0432)Cons.

for one of the parties. Jones, 334 Ill. App. 3d at 418. Our courts have also invalidated

liquidated damages clauses based on public policy concerns where the purpose of the clause is to

punish nonperformance rather than estimate damages. Stride, 132 Ill. App. 3d at 605. In the case

at bar, the Hy-Vee Holdback must be invalidated based on public policy concerns for both of

these reasons because it amounts to a windfall for Buyer and a penalty for Seller's 91-day

"nonperformance" delay.

¶ 58   The Hy-Vee Holdback constitutes an unenforceable penalty clause because the provision

amounted to a windfall recovery for Buyer. Here, the trial court awarded Buyer the entire $4.3

million for only a 91-day delay in approving construction permits even though the entire 20 to

45-year lease was still intact and Buyer would receive the benefits of that lease for the next 20 to

45 years. The damages awarded from the Hy-Vee Holdback, $4.3 million, are grossly

disproportionate to the loss Buyer could have sustained in the event of a delay in obtaining

construction permits. In essence, the trial court has allowed Buyer to receive a double recovery

by not paying the $4.3 million purchase price for the Hy-Vee lease while still recovering the $4.3

million for the Hy-Vee lease over the next 20 years plus.

¶ 59   The evidence at trial shows that the purpose of the Hy-Vee Holdback was to compensate

Buyer for the full value that it would have lost in the event that the Hy-Vee Expansion did not

take place. Buyer’s primary negotiator, Tom Rogers, testified that the Hy-Vee Holdback was a

calculation of the present value of the Hy-Vee Expansion. To arrive at this figure, Rogers

determined that the new Hy-Vee Lease would generate an incremental income of $430,000 per

year. From there, Rogers calculated that the Hy-Vee Expansion’s capitalization rate would be

                                                 29
1-11-2802)
1-12-0432)Cons.

10%, which is the percentage of the property’s cost that would be paid by the net proceeds from

the Hy-Vee Lease. To determine the present value of the Hy-Vee Expansion, Rogers then

divided the annual income by the capitalization rate. The final figure, $4.3 million, represented

the value of the Hy-Vee Expansion in consideration of the Hy-Vee Lease. Buyer argues that the

this figure was just a middle ground estimate that calculated losses over a 10-year period, and

points to the trial court’s finding that the parties arrived at an in-between valuation by calculating

the annual income with a multiplier of 10. This, however, misunderstands the nature of a

capitalization rate, which is commonly used to calculate the present value of commercial real

estate. The evidence shows that the negotiations focused on using the capitalization to determine

the purchase price of Hy-Vee Expansion, and not just merely multiplying the expected annual

income by 10.

¶ 60   By contrast, Buyer’s actual damages from the breach are significantly less. Though

neither party provides an exact figure of Buyer’s actual damages, the evidence at trial is

instructive in arriving at a reasonable figure. Seller points to Buyer’s November 16 proposal in

which Buyer contemplated extending the October 31, 2005 deadline in exchange for Seller

paying Buyer for rent that it would have been paid had the permits been approved on time. The

payments consisted of monthly payments of $47,000, plus a pro rata share of real estate taxes and

CAM. Though Seller claims that this figure is inflated, it is far closer to the actual damages

sustained in the event of a delay than the damages awarded by the Hy-Vee Holdback. Thus,

Buyer was conferred a substantial windfall when it was awarded the full $4.3 million value of the

                                                 30
1-11-2802)
1-12-0432)Cons.

Hy-Vee Holdback for a temporary delay that Buyer had attempted to settle for a significantly

lesser amount.3

¶ 61   Buyer claims that the damages were reasonable and not an excessive windfall because the

magnitude of potential damages at the time of the contract was great. Buyer argues that, had the

deadline not been met, the future of the Hy-Vee Expansion could have potentially been in

jeopardy. If the Hy-Vee Expansion had not been completed, the Mall could have lost significant

value, and the vacancy of a major anchor store could have hurt the Mall's ability to attract future

tenants, which would damage the Mall’s viability. However, there is scant evidence, if any, that

the Hy-Vee Expansion was in danger of complete failure. A new Hy-Vee Lease had been signed,

final plans and specifications had been approved, asbestos removal had been completed, and

construction had begun on parking lot improvements. The appellate record does not show that

either party had a significant obstacle that would endanger the completion of the Hy-Vee

Expansion. In fact, the only delay in delivery of the premises was due to the approval of

construction permits, which had been applied for before the deadline expired. As such, the Hy-

Vee Expansion was completed in November 2006, at which point Hy-Vee began making rent

payments under its new lease. Such a scenario was not unforeseeable when the parties executed

        3 Further, it appears that Buyer did not suffer any "lost" rent as the 20-plus-year lease was
merely pushed back 91 days. Buyer will still received the entire profit anticipated from the 20-
year lease.

                                                 31
1-11-2802)
1-12-0432)Cons.

the Deed and Money Escrow in 2004. The parties thus erred in negotiating a damages provision

that conferred an unreasonably large recovery for a minor delay.

¶ 62   Further, there is nothing in the evidence to suggest that if the Hy-Vee lease did not go

through, that the space formerly rented by Wal-Mart could not be rented to anyone else for

twenty years. Thus, Buyer's arguments about speculative and incredible potential damages do

not change the fact that allowing Buyer to keep the $4.3 million and make an additional $4.3

million over the next 20 years was an unreasonable windfall.

¶ 63   Penske Truck Leasing Co., is instructive here. In Penske Truck Leasing Co., the lessor of

a vehicle lease agreement brought suit against the guarantor, and sought enforcement of the

lease’s liquidated damages provision. Penske Truck Leasing Co., 311 Ill. App. 3d at 457-58.

The liquidated damages clause in the agreement provided different methods of calculating

damages for the non breaching lessor depending on whether it retained or sold the vehicles. Id.

at 457. By calculating the damages before it sold the vehicles, the lessor was able to then sell the

vehicles afterwards for a windfall. Id. Based on this, the appellate court found that the

liquidated damages provision was unenforceable because the parties did not intend for the lessor

to reap a windfall, and that “the award entered by the trial court [thereunder] was well in excess

of the actual damages suffered by [the lessor].” Id. The appellate court remanded the case to the

trial court with instructions to calculate damages using a formula that more accurately reflected

the lessor’s actual losses. Id. In the instant case, the damages provision similarly provided Buyer

with a windfall recovery well in excess of the actual damages suffered.

                                                32
1-11-2802)
1-12-0432)Cons.

¶ 64   Buyer argues that Penske Truck Leasing Co., is distinguishable because the appellate

court ultimately enforced the liquidated damages provision, finding that “the agreement provided

for an enforceable liquidated-damages provision and not an unenforceable penalty.” Id. at 455-

56. Though the appellate court reversed in part and remanded the case back to the trial court, it

did so because it found that the trial court applied the incorrect formula for determining the

amount of damages to be awarded for the complained default. Id. at 457-58. Buyer’s argument

mischaracterizes the central finding in the case. Penske Truck Leasing Co., states:

                       “In the instant case, *** paragraph 15 of the agreement

               provides alternative methods of computing damages. One method

               is applicable if plaintiff decides to sell the vehicles, while another

               method is used if plaintiff retains the vehicles. The trial court

               awarded damages based upon the method which assumed that

               plaintiff retained the vehicles. While Mr. Douglas testified that

               plaintiff initially decided to retain the vehicles because of a

               depressed market, the evidence is clear that plaintiff ultimately sold

               all four vehicles for $30,400 each. We are certain that it was never

               the intention of the parties to permit plaintiff to proceed under the

               method of recovery used when plaintiff decides to retain the

               vehicle but later sell the vehicles and reap a windfall in the process.

               If we allowed plaintiff to proceed in this manner, the damages

                                                 33
1-11-2802)
1-12-0432)Cons.

               would be so unreasonable that we should refuse to enforce the

               provisions of paragraph 15, and that paragraph would have to be

               considered a penalty provision.” Id. at 457.

Thus, the appellate court found that the relevant provision upon which the parties calculated

damages was unenforceable as a penalty because it conferred a windfall on the non-breaching

party far in excess of the actual damages that it sustained.

¶ 65   Buyer also claims that, though the amount of liquidated damages awarded to Buyer may

have been greater than the amount of actual damages it sustained, Illinois courts have held that

“[t]he nature of a liquidated damages provision is such that the set amount may at times exceed

actual damages.” Karimi v. 401 North Wabash Venture, LLC, 2011 IL App (1st) 102670, ¶ 27.

Buyer also points to comment (b) in section 356 of the Restatement (Second) of Contracts, which

states that a fixed amount of liquidated damages is reasonable “to the extent that it approximates

the [actual] loss anticipated at the time of the making of the contract, even though it may not

approximate the actual loss.” Restatement (Second) of Contracts § 356 cmt. (b) (1979). Buyer

argues that at the time the parties executed the Third Amendment in 2004, the Hy-Vee Holdback

was a middle-ground estimate of what the potential damages may have been, and that the

liquidated damages provision was enforceable even though the resulting damages from a breach

could have been potentially higher or lower than the actual damages depending on any number of

scenarios that may have unfolded.

                                                 34
1-11-2802)
1-12-0432)Cons.

¶ 66     Although liquidated damages may at times exceed the amount of actual damages, a

damages clause providing “ ‘unreasonably large liquidated damages is unenforceable on grounds

of public policy as a penalty.’ ” Penske Truck Leasing Co., 311 Ill. App. 3d at 454 (quoting

Restatement (Second) of Contracts § 356 (1979)). As stated above, the damages awarded by the

Hy-Vee Holdback for a delay in permit approval were unreasonably large because they far

exceeded the amount of actual damages that Buyer sustained, thus resulting in a windfall to

Buyer.

         ¶ 67 3. The Purpose of the Hy-Vee Holdback Was to Secure Performance/Punish
                                       Nonperformance.

¶ 68     We also find that the Hy-Vee Holdback was intended to secure performance and to

punish nonperformance. It is a general rule of contract law that, for reasons of public policy, a

liquidated damages clause which operates as a penalty for nonperformance will not be enforced.

Jameson Realty Group, 351 Ill. App. 3d at 422; Stride, 132 Ill. App. 3d at 605 ("if the clause

fixing damages is merely to secure performance of the agreement, it will be treated as a penalty

and only actual damages proved can be recovered"). Given that the Hy-Vee Holdback of $4.3

million has no reasonable relation to damages caused by a 91-day delay in obtaining permits, the

clause was not intended to measure damages in the event of a delay, but rather intended to be a

punishment in the event of a delay.

¶ 69     In Telenois, Inc. v. Village of Schaumburg, 256 Ill. App. 3d 897 (1993), a cable television

franchise, Telenois, entered into a franchise agreement with the Village of Schaumburg whereby

                                                 35
1-11-2802)
1-12-0432)Cons.

Telenois would provide cable services to the Village's residents. Within the franchise agreement,

there was a clause that stated: "'This system reconfiguration will be completed by December 13,

1988. Franchisee will provide the Village with an unconditional Letter of Credit in the amount

of One Hundred Thousand Dollars ($100,000) to be payable to the Village. In the event the

Franchisee fails to complete this reconfiguration by December 31, 1988, the Village will collect

the amount as a penalty.'" Id. at 899. Telenois completed 99% of the reconfiguration by January

1989. The reason for the delay was due to the fact that Telenois could not complete the

conversion without gaining access to some of the subscriber's homes. Despite the fact that the

configuration was 99% complete and the reason for the delay was not within Telenois' control,

the village collected the entire $100,000. The trial court ruled that the clause amounted to an

unenforceable penalty clause against public policy, and on appeal, the appellate court agreed.

¶ 70   Like the contract clause in Telenois, the Hy-Vee Holdback clause states that Buyer would

keep the $4.3 million if all the conditions were not met by a certain date, regardless of whether

the conditions were never met at all or met after a slight delay. Further, like the delay that

resulted in Telenois, which Telenois had no control over, here the 91-day delay that resulted was

not within the control of Seller, as Hy-Vee was responsible for obtaining the necessary permits.

While the appellate court in Telenois noted that the village's witness acknowledged the clause in

that contract to be a "penalty," here, by conceding in the November 16 proposal that delay

damages per month would be drastically less that the entire $4.3 million Hy-Vee Holdback,

Buyer has impliedly conceded that the $4.3 million does not reflect damages for a 91-day delay.

                                                 36
1-11-2802)
1-12-0432)Cons.

Thus, because both the clause at issue here and the clause that was struck down in Telenois

operate in the same manner and have the same all-or-nothing effect, the $4.3 million Hy-Vee

Holdback clause was not meant to measure damages resulting from a slight delay in performance

and must not be enforced.4

¶ 71   Buyer argues, though, that Illinois courts have recognized the validity of a liquidated

damages clause in cases where a party’s performance is delayed, even when the non-breaching

party has not suffered any actual damages. In making this argument, Buyer relies on Bethlehem

Steel Corp. v. City of Chicago, 350 F.2d 649 (7th Cir. 1965), which is the same case the trial

court relied on in concluding that the liquidated damages clause here was enforceable. In

Bethlehem Steel, Bethlehem contracted to sell steel to the City of Chicago as a part of the Dan

Ryan Expressway construction project, which the city wanted to have completed by a certain

date. Bethlehem Steel, 350 F.2d at 650-51. The contract provided that Bethlehem would deliver

steel by the deadline or it would be liable for liquidated damages. Id. at 651. Though Bethlehem

delivered the steel 52 days late, the construction was completed on schedule. Id. Bethlehem

argued that the City of Chicago was not entitled to liquidated damages because it had not

incurred any harm or actual damages. Id. The Seventh Circuit rejected Bethlehem’s argument,

       4  Further, as noted by the Seventh Circuit, Illinois courts continue to invalid liquidated
damage clauses even where both parties are economically sophisticated. Checkers Eight Ltd.
Partnership, 241 F.3d at 563 (citing Telenois, 256 Ill. App. 3d 897); Grossinger Motorcorp, Inc.,
240 Ill. App. 3d 737. Thus, any argument that the parties were sophisticated in this case should
hold little to no weight.

                                                37
1-11-2802)
1-12-0432)Cons.

finding that “Bethlehem now seeks to re-write the contract and to relieve itself from the

stipulated delivery dates for the purposes of liquidated damages, and to substitute therefor the

City’s target date for the scheduled opening of [its] super highway. This [Bethlehem] cannot

do.” Id. In finding a valid liquidated damages clause, the Seventh Circuit relied on Wise v.

United States, 249 U.S. 361 (1919), which found that courts "'look with candor, if not with favor,

upon such provisions in contracts when deliberately entered into between parties who have

equality of opportunity for understanding and insisting upon their rights, as promoting prompt

performance of contracts and because adjusting in advance, and amicably, matters the settlement

of which through courts would often involve difficulty, uncertainty, delay and expense.'"

Bethlehem Steel, 350 F.2d at 651 (quoting Wise, 249 U.S. at 366).

¶ 72   However, Bethlehem is distinguishable from the instant case because the liquidated

damages clause there provided a specific calculation for delay as a linear function of time at a

rate of $1,000 per day. Bethlehem Steel, 350 F.2d at 650. In doing so, the damages clause

provided a reasonable amount of damages for delayed performance because each day of delay

affected the other parties’ ability to perform, which justified the amount of damages. Id. at 651.

¶ 73   In the case at bar, the Hy-Vee Holdback does not distinguish between minor delays in

performance and a complete failure of the Hy-Vee Expansion, and there is certainly no per-day

damage rate that was contemplated by the parties. “The element common to most liquidated

damages clauses that get struck down as penalty clauses is that they specify the same damages

regardless of the severity of the breach.” Xco International. Inc. v. Pacific Scientific Co., 369

                                                 38
1-11-2802)
1-12-0432)Cons.

F.3d 998, 1004 (7th Cir. 2004) (citing Checkers Eight Ltd. Partnership, 241 F.3d at 562, Lake

River Corp. v. Carborundum Co., 769 F.2d 1284, 1290 (7th Cir. 1985), M.I.G. Investments, Inc.

v. Marsala, 92 Ill. App. 3d 400 (1981), and Kalenka v. Taylor, 896 P.2d 222, 228-29 (Alaska

1995)). “[T]he damages contained in a liquidated damages clause must be for a specific amount

for a specific breach; the provision may not merely serve as a threat to secure performance or as a

means to punish nonperformance.” Jameson, 351 Ill. App. 3d at 424 (citing Noffsinger, 311 Ill.

App. 3d at 860); see also Builder’s Concrete Co. of Morton v. Fred Faubel & Sons, Inc., 58 Ill.

App. 3d 100, 107 (1978) (A liquidated damages clause “must be a specified amount for a

specific breach to be paid as an alternative to performance and not as a penalty for

nonperformance.”).

¶ 74    It is undisputed that the Hy-Vee Holdback provided the same amount of damages

regardless of the type or extent of the breach. “When a contract specifies a single sum in

damages for any and all breaches even though it is apparent that all are not of the same gravity,

the specification is not a reasonable effort to estimate damages; and when in addition the fixed

sum greatly exceeds the actual damages likely to be inflicted by a minor breach, its character as a

penalty becomes unmistakable.” Lake River Corp., 769 F.2d at 1290; see also Checkers Eight

Ltd. Partnership, 241 F.3d at 562 (“If the amount of damages is invariant to the gravity of the

breach, the clause is probably not a reasonable attempt to estimate actual damages and thus is

likely a penalty.”).

                                                39
1-11-2802)
1-12-0432)Cons.

¶ 75   For the foregoing reasons, the Hy-Vee Holdback is unenforceable as it functions as a

penalty where it fails to distinguish between a minor delay in permit approval and a complete

failure of the construction project. As such, the Hy-Vee Holdback sought to award the entire

value of the Hy-Vee Expansion for a temporary delay, which constitutes an unenforceable

penalty to coerce performance rather than a valid liquidated damages provision.

¶ 76   In sum, because the Hy-Vee Holdback (1) does not meet the three requirements necessary

under Jameson to validate a liquidated damages clause, (2) results in a windfall to Buyer, and (3)

functions as a penalty for nonperformance, we find it to be invalid and unenforceable. Because

Buyer is entitled to any actual damages it suffered as a result of the 91-day delay, we remand this

cause to the trial court to afford Buyer an opportunity to prove its actual damages. See

Grossinger Motorcorp, Inc., 240 Ill. App. 3d at 752 (after liquidated damages clause is held to be

unenforceable, defendant is entitled to actual damages, if any can be proven).

¶ 77   Seller also claims that the trial court erred in finding that the Deed and Money Escrow

was ambiguous, and that the trial court violated several principles of contract interpretation when

construing the terms of the parties’ agreement. Since we find that the Hy-Vee Holdback is an

unenforceable penalty, we need not address these contentions.

                                       ¶ 78 B. Attorney Fees

¶ 79   Seller argues that the trial court erred as a matter of law in failing to award it attorney fees

under the Reaffirmation Agreement executed by Buyer prior to closing on December 14, 2004.

Under the agreement, Buyer promised to “indemnify and hold harmless Sellers and each of them

                                                 40
1-11-2802)
1-12-0432)Cons.

from and against any and all loss, cost, debt, damage (including court costs and reasonable

attorney fees) for liability arising out of, directly or indirectly, the failure of any Assignee to

perform the Undertakings pursuant to its assignment or arising out of its need to enforce the

terms of this Reaffirmation, or both.” However, the parties agree that an award of attorney fees

under the Reaffirmation Agreement is contingent on the existence of a breach by Buyer. We

remand to the trial court to decide the issue of breach by Buyer, which could include reasonable

court costs and attorney fees.

                                       ¶ 80 C. Buyer’s Appeal

¶ 81    With regard to Buyer’s appeal, Buyer claims that the trial court’s order denying post-

judgment interest was in error because it deprived Buyer of its statutory right. However, we need

not consider this issue since there is no money award.

                                         ¶ 82 III. Conclusion

¶ 83    For the foregoing reasons, the trial court’s order awarding the $4.3 million held in escrow

to Buyer is reversed. Upon remand, the trial court is directed to afford buyer an opportunity to

prove actual damages it suffered as a result of the 91-day delay, deduct such damages from the

escrow to be awarded to Buyer, and order the release of the remaining funds to Seller. Seller’s

claim concerning attorney fees is also remanded to the trial court with instructions to decide the

issue of breach by Buyer, including the issue of attorney fees and costs.

¶ 84    In light of the ruling that Buyer is not entitled to the $4.3 million holdback we need not

consider the issue of whether Buyer is entitled to post-judgment interest.

                                                   41
1-11-2802)
1-12-0432)Cons.

¶ 85   Affirmed in part and reversed in part with instructions.

                                               42