Court Opinion

ID: 4504607
Source: CourtListenerOpinion
Date Created: 2020-02-05 15:06:28.792572+00
Date Added: 2024-06-11T08:49:41.082357
License: Public Domain

NOT FOR PUBLICATION WITHOUT THE
                               APPROVAL OF THE APPELLATE DIVISION
        This opinion shall not "constitute precedent or be binding upon any court." Although it is posted on the
     internet, this opinion is binding only on the parties in the case and its use in other cases is limited. R. 1:36-3.

                                                         SUPERIOR COURT OF NEW JERSEY
                                                         APPELLATE DIVISION
                                                         DOCKET NO. A-2418-18T2

WOODSTONE GROUP, LLC,

          Plaintiff-Respondent,

v.

PAUL TREACY and SARAH
TREACY,

     Defendants-Appellants.
____________________________

                    Argued telephonically December 17, 2019 –
                    Decided February 5, 2020

                    Before Judges Yannotti and Firko.

                    On appeal from the Superior Court of New Jersey, Law
                    Division, Morris County, Docket No. L-0639-17.

                    David M. Miller argued the cause for appellants (Miller
                    and Miller, attorneys; David M. Miller, on the briefs).

                    Michael Patrick Carroll argued the cause for respondent
                    (Nish & Nish, attorneys; Robert J. Nish, on the brief).

PER CURIAM
      Defendants Paul and Sarah Treacy appeal from a judgment entered by the

Law Division on January 3, 2019, which awarded plaintiff Woodstone Group,

LLC, $33,323.20 plus interest and costs, and dismissed defendants'

counterclaims. We affirm.

                                       I.

      Plaintiff filed a complaint in the Law Division, alleging that in March

2012, the parties entered into a written contract, which required plaintiff to

perform certain work at defendants' home, for a total of $158,100. Plaintiff

claimed the parties amended the agreement to include additional work, at a cost

of at least $8,188.40.

      Plaintiff alleged that after it performed substantially all of the work,

defendants terminated the contract "without cause" and refused to permit

plaintiff to complete the project. Plaintiff claimed defendants failed to pay the

amount due under the contract. Plaintiff asserted claims for breach of contract

and quantum meruit. Plaintiff sought damages, interest, attorney's fees, and

costs of suit.

      Defendants filed an answer, affirmative defenses, and counterclaims.

Defendants asserted claims for violations of the New Jersey Consumer Fraud

Act (CFA), N.J.S.A. 56:8-1 to -20, common law fraud, breach of contract,

                                                                         A-2418-18T2
                                       2
breach of the duty of good faith and fair dealing, breach of express and impl ied

warranties, unjust enrichment, and negligence. Among other things, defendants

alleged that plaintiff violated the CFA by failing to comply with regulations

adopted pursuant to the CFA, which govern home improvement practices (the

HIP regulations), N.J.A.C. 13:45A-16.1 to -16.2. Defendants also claimed that

plaintiff performed certain work in a careless, negligent, or unprofessional

manner.

      The matter was tried before the Law Division judge, sitting without a jury.

Plaintiff's principal Christopher J. Saul testified that on March 9, 2012, the

parties entered into a written contract which required plaintiff to make certain

improvements to defendants' home in accordance with plans prepared by

defendant's architect, Jerry A. Bruno, Jr. The contract required plaintiff to

remove a portion of the rear of the house, excavate and build a new foundation,

and construct a new eat-in kitchen, pantry, bathroom, and deck.

      Saul explained that the initial contract price was about $147,900, and the

parties agreed to add "two other components," specifically an upgrade to the

electrical system and placement of a stone veneer on the home's foundation. The

total agreed-upon contract price was $158,100.          The contract required

                                                                         A-2418-18T2
                                       3
defendants to make an initial deposit of $29,580, four installment payments of

$29,000, and a final payment of $2320 upon completion of the project.

      Defendants also were required to pay for, among other things, permit

fees, specialty lighting, and appliances. The contract stated that the project

"should take approximately [three to four] months to complete" but the

completion date could be affected by the weather, availability of supplies, and

labor shortages. Defendants made the initial deposit of $29,580.

      On March 22, 2012, the Township of Chatham's construction department

approved the plans and issued a building permit for the project. Plaintiff began

the work in April 2012, and defendants made the first installment payment of

$29,000. The work continued and on June 14, 2012, defendants paid the second

installment of $29,000. On July 23, 2012, defendants paid the third installment

of $29,000. Mrs. Treacy asked Saul to adjust the wall in the kitchen area, and

he agreed to make that change without any additional charge.

      Saul testified that the fourth installment of $29,000 had been due after the

second delivery of the cabinets.     Defendants did not make that payment.

Towards the end of August 2012, Mrs. Treacy left the United States for a

vacation and was away for about two weeks. Saul said that during that time,

plaintiff did not have access to the house and performed only a minimum amount

                                                                          A-2418-18T2
                                        4
of the work.     According to Saul, when Mrs. Treacy returned, she did not

complain about the work. He again asked her to pay the $29,000 installment.

Defendants did not make the payment.

      Saul stated that, in September 2012, plaintiff only had certain

"miscellaneous carpentry, trim and details" to complete. On September 7, 2012,

Bruno inspected the work and, several days later, he provided plaintiff with a

punch list of work to be completed. Saul testified that plaintiff completed most

of the items on the list.

      Saul stated that at this time, Mrs. Treacy asked plaintiff to complete the

project without payment because she wanted to obtain a home equity line of

credit to pay for the work. Saul denied the request. He said plaintiff could not

work without getting paid. On September 18, 2012, Mr. Treacy gave Saul a

check for $10,000.

      In October 2012, Saul ordered replacement cabinets, at Mrs. Treacy's

request, and plaintiff paid $2,283.44 for the new cabinets. Defendants did not

pay plaintiff for the replacement cabinets. Saul stated that, in addition to the

unpaid installments, plaintiff was seeking payment for the time lost while Mrs.

Treacy was away, the building permits, and a window upgrade. Plaintiff's total

claim was $42,166.44.

                                                                        A-2418-18T2
                                       5
      On cross-examination, Saul acknowledged that during the summer of

2012, plaintiff removed the chimney and installed a pipe through the wall to

vent the furnace and water heater. He also acknowledged that on October 18,

2012, a municipal official came to the property and issued a notice of violation,

which stated that the chimney had been removed without a permit, a fire permit

was required for venting the furnace, and the furnace and water heater were not

vented properly. The notice also stated that the vent connector was too close to

"combustibles."

      Mrs. Treacy testified for defendants. She denied that defendants needed

a home equity line of credit to pay plaintiff. She stated that after the municipal

official issued the notice of violations in October 2012, she did not want plaintiff

back at her home for safety reasons. She claimed that as a result of the improper

venting of the furnace and water heater, defendants and their children were

exposed to dangerous health conditions.

      Mrs. Treacy asserted that plaintiff did not complete the work in a timely

manner. She stated that plaintiff ordered the wrong-sized door, and defendants

were forced to pay to correct deficiencies in the ventilation of the furnace and

water heater. She said the plans did not require plaintiff to remove the existing

chimney, and plaintiff failed to obtain the necessary permits for the work. Mrs.

                                                                            A-2418-18T2
                                         6
Treacy claimed the improper venting of the furnace and water heater made the

home uninhabitable. She asserted that plaintiff never obtained written change

orders and did not complete the plumbing work. She denied that her absence

interfered with the work.

      Mrs. Treacy further testified that she paid plaintiff an additional $5000 in

cash, but she had no documentation to confirm the payment. She explained that

defendants were seeking treble damages for the amount they spent to install a

new furnace and new water heater with proper venting. Defendants also were

seeking compensation for the amounts paid to replacement contractors to

complete the work, and for the replacement cabinets. Defendants also were

seeking counsel fees and costs.

      Defendants presented testimony from Albert J. Oldroyd, Jr., who was

qualified as an expert in the field of plumbing. He stated that a water heater can

be vented through the chimney or directly out of the house through a wall,

ceiling, or roof. He said that if he was going to change the venting of a water

heater from a chimney, a permit was required. He opined that $1800 was a

reasonable price to install a new direct-vent water heater, but this would depend

on the work involved in the installation.

                                                                          A-2418-18T2
                                        7
      Bruno also testified for defendants. He stated that removal of the existing

chimney was one option in his plans. He said that in September 2012, he

prepared his punch list of work that remained to be completed. On cross-

examination, Bruno acknowledged that, aside from the change in the cabinets,

the items on the punch list were "cosmetic finishes." However, on redirect,

Bruno stated that certain items on the list, such as the installation of the sink and

dishwasher, and the relocation of a heating, ventilation and air conditioning

(HVAC) duct, were not "cosmetic."

      In addition, Gregory Impink, the Township's construction official,

testified that he was familiar with the notice of violation that the Township's

plumbing subcode official issued on October 18, 2012. Plaintiff did not file an

appeal regarding the notice, and plaintiff never applied to the Township for a

permit to remove the chimney. He also stated that a permit is required to remove

a chimney; however, he acknowledged that sometimes the Township issues the

permit after the contractor has completed the work.

      Impink further testified that in March 2012, he reviewed the plans for the

work at defendants' home, and they included an option for removal of the

existing chimney. He stated that he issued a building permit for the project but

the permit did not authorize plaintiff to remove the chimney, and the Township

                                                                             A-2418-18T2
                                         8
never issued a permit for that work. He also said the Township's building code

does not permit a furnace or water heater to be used if it is not properly vented.

      Robert Rafter testified for defendants as an expert in HVAC. He stated

that furnaces of the sort in defendants' home are usually vented through a

chimney or a B-vent, which is a double-wall metal chimney. He recommended

replacement of defendants' furnace with a high-efficiency, direct-vented

furnace, because the furnace was old and it would be more cost effective to

install a new, direct-vented furnace.

      Rafter performed the work and charged defendants $3900. He did not

obtain a permit because he believed the work was covered by the plumbing

permit the Township previously issued.

      In addition, Mr. Treacy testified that defendants did not make the fourth

payment due under the contract because plaintiff did not complete the work. He

told plaintiff to stop work on the project because of the dangerous condition in

the home, which he claimed resulted from the improper venting of the furnace

and water heater.

      Mr. Treacy also stated that plaintiff did not install the cabinets correctly

and they did not fit. He admitted that Mrs. Treacy had ordered a 48-inch range

for the kitchen, when a 42-inch range was required.

                                                                          A-2418-18T2
                                        9
                                       II.

      The trial judge filed a written opinion in which he concluded that

defendants breached the contract because plaintiff substantially performed all of

the work and defendants failed to pay all of the amounts due under the contract.

The judge found that defendants' testimony that the work was deficient "was

simply not believable." The judge stated that the alleged defects "were cosmetic

at best."

      The judge noted that defendants alleged that the removal of the chimney

had created a dangerous condition in the home. The judge found, however, that

the evidence presented at trial did not support that conclusion. The judge noted

that the Township had issued the stop work order because plaintiff had removed

the chimney without a permit.

      The judge stated that the inspector who issued the violations never went

inside the home, and Impink testified that the Township could issue a permit for

the removal of a chimney after the work was completed. The judge noted that

the plans Bruno prepared included an option for removal of the existing

chimney, and the Township had approved the plans. The judge found that, under

the circumstances, plaintiff should have appealed and challenged the Township's

notice of violation.

                                                                         A-2418-18T2
                                      10
      The judge further found that after defendants removed plaintiff from the

job, the additional work performed at the home was an upgrade from the work

plaintiff had completed. The judge stated that defendants suffered no damages.

Defendants paid for replacement cabinets, but plaintiff had already paid for the

cabinets, and defendants should have sought a refund.

      The judge also stated that Oldroyd "waffled" on the issue of direct, outside

venting and that Oldroyd conceded he never personally inspected the premises.

He also found that Mrs. Treacy did not make the necessary choices of appliances

and other items, which would have allowed plaintiff to complete the job in a

timely manner. The judge noted that Mrs. Treacy had ordered the wrong-size

range.

      In addition, the judge found that Mrs. Treacy "waffled" on the amount she

spent for the appliances, and on her claim that she made an additional $5000

cash payment to plaintiff. The judge stated that Mrs. Treacy "equivocated about

complaining to plaintiff about the delay." He found that Mrs. Treacy never gave

plaintiff the opportunity to correct or cure the deficiencies.

      The judge concluded that the evidence showed plaintiff completed the

punch list items and it was entitled to be paid the amounts due under the contract.

The judge rejected plaintiff's claim for lost work and awarded plaintiff

                                                                           A-2418-18T2
                                       11
$33,323.20. In addition, the judge dismissed defendants' counterclaims, finding

that the claims were lacking in merit.

      The judge stated that defendants did not submit sufficient evidence to

support their claims under the CFA. The judge found that plaintiff did not

perpetrate a fraud on defendants. The judge also found that defendants were not

harmed by any technical violations, if they existed, and that it would be

inequitable to relieve defendants of their obligation to pay plaintiff for the

completed work. The judge also decided that plaintiff was entitled to recover

the amounts due under the doctrine of quantum meruit.

      The judge memorialized his decision in a judgment dated January 3, 2019,

which awarded plaintiff $33,323.20, plus interest and costs, and dismissed

defendants' counterclaims with prejudice. Defendants' appeal followed.

                                         III.

      We turn first to defendants' argument that the trial judge erred by awarding

plaintiff the amounts due under the contract. Defendants contend plaintiff failed

to establish it substantially completed the work. Defendants claim plaintiff

created a dangerous condition in the home when it removed the chimney and

failed to properly vent the furnace and water heater.

                                                                          A-2418-18T2
                                         12
      Defendants also maintain that plaintiff was obligated to correct the

venting of the furnace and water heater but failed to do so. Defendants claim

they were required to hire a contractor to remedy the dangerous condition, and

they spent "significant sums" in doing so. They therefore assert that plaintiff

was not entitled to recover the entire amount due under the contract.

      We note that factual findings "made by the trial court sitting in

a non-jury case are subject to a limited and well-established scope of review

. . . ." Seidman v. Clifton Sav. Bank, S.L.A., 205 N.J. 150, 169 (2011) (citing

In re Trust Created by Agreement Dated Dec. 20, 1961, ex. rel. Johnson, 194
N.J. 276, 284 (2008)). We will not "disturb the factual findings and legal

conclusions of the trial judge unless we are convinced that they are so manifestly

unsupported by or inconsistent with the competent, relevant and reasonably

credible evidence as to offend the interests of justice . . . ." Ibid. (quoting In re

Trust, 194 N.J. at 284).

      Our deference to the trial court's factual findings "is especially

appropriate" where, as in this case, "the evidence is largely testimonial and

involves questions of credibility." Ibid. (quoting Cesare v. Cesare, 154 N.J.
394, 411-12 (1998)). The trial court's decisions on issues of law are, however,

subject to plenary review. Manalapan Realty, L.P. v. Twp. Comm. of

                                                                             A-2418-18T2
                                        13
Manalapan, 140 N.J. 366, 378 (1995). "A trial court's interpretation of the law

and the legal consequences that flow from established facts are not entitled to

any special deference." Ibid.

      Generally, a builder who "substantially perform[s]" the contract is entitled

"to recover the contract price less . . . a fair allowance to the owner to make

good the defects . . . ." R. Krevolin & Co. v. Brown, 20 N.J. Super. 85, 89 (App.

Div. 1952) (internal quotations omitted) (quoting Reese v. Kline Bldg. & Const.

Co., 8 N.J. Misc. 296, 297 (1930)); see also Power-Matics, Inc. v. Ligotti, 79
N.J. Super. 294, 303 (App. Div. 1963). "Substantial performance is compliance

in good faith with all important particulars of the contract." Jardine Estates, Inc.

v. Donna Brook Corp., 42 N.J. Super. 332, 337 (App. Div. 1956).

      Here, defendants do not assert that plaintiff failed to perform the work

required by the contract or the work identified on the punch list. They assert,

however, that plaintiff removed the existing chimney without a permit and

improperly installed a temporary venting mechanism for the furnace and water

heater. It is undisputed that on October 18, 2012, the Township's inspector

issued a notice of violation, which stated that the chimney had been removed

without a permit, the existing furnace and water heater were not properly vented,

                                                                            A-2418-18T2
                                        14
the vent connector was too close to "combustibles," and a fire permit was

required for venting the furnace.

      Defendants contend plaintiff was obligated to correct the venting problem

identified in the notice. They argue that "[n]othing prevented plaintiff from

fulfilling its contractual obligation; it simply chose not to do so." The record

shows, however, that defendants ordered plaintiff off the job and thereby

prevented it from correcting the venting problem.

      We conclude there is sufficient credible evidence to support the trial

court's finding that plaintiff substantially completed the work required by the

contract, and that plaintiff could not correct the deficiency in the venting of the

furnace and water heater because defendants ordered plaintiff to stop working

on the project. Thus, there is sufficient evidence in the record to support the

trial court's decision to award plaintiff all the monies due under the contract.

                                      IV.

      We turn to defendants' contention that the trial court erred by denying

them relief on their claim under the CFA. Defendants contend they established

that plaintiff violated the CFA, and that they are entitled to damages for the

ascertainable losses they sustained as result of the violations.

                                                                           A-2418-18T2
                                       15
      "To prevail on a CFA claim, a plaintiff must establish three elements: '1)

unlawful conduct by defendant; 2) an ascertainable loss by plaintiff; and 3) a

causal relationship between the unlawful conduct and the ascertainable loss.'"

Zaman v. Felton, 219 N.J. 199, 222 (2014) (quoting Bosland v. Warnock Dodge,

Inc., 197 N.J. 543, 557 (2009)).

      The CFA authorizes the Attorney General to promulgate certain rules and

regulations, the violation of which "gives rise to a discrete category of CFA

violations." Perez v. Professionally Green, LLC, 215 N.J. 388, 400 (2013)

(citing N.J.S.A. 56:8-4; Cox v. Sears Roebuck & Co., 138 N.J. 2, 17 (1994)).

Violations of the HIP regulations are deemed to be violations of the CFA. Allen

v. V & A Bros., Inc., 208 N.J. 114, 129 (2011).

      On appeal, defendants claim plaintiff did not comply with several HIP

regulations.   First, defendants assert plaintiff violated N.J.A.C. 13:45A-

16.2(a)(7)(ii), which states it is unlawful to "[f]ail to . . . complete work on the

date or within the time period specified in the home improvement contract . . . ,

unless the delay is for reason of labor stoppage; unavailability of supplies or

materials, unavoidable casualties, or any other cause beyond the seller's

control."

                                                                            A-2418-18T2
                                        16
      Defendants also assert plaintiff did not comply with N.J.A.C. 13:45A-

16.2(a)(12), which requires that "all changes in the terms and conditions" of

home improvement contracts be in writing and signed by all parties. In addition,

defendants claim plaintiff violated N.J.A.C. 13:45A-16.2(a)(10)(i), which states

that no home improvement contractor "shall commence work until [the

contractor] is sure that all applicable state or local building and construction

permits have been issued as required . . . ."

      Plaintiff does not dispute that the HIP regulations apply to its contract

with defendants. As stated previously, the contract provided that "[t]he project

should take approximately [three to four] months to complete" but the

completion date could be affected by the weather, availability of supplies, and

labor shortages. Here, the Township issued the building permit in March 2012,

and the work commenced around that time. Saul admitted the work was not

completed within three or four months after the work began. Defendants failed

to show, however, that they sustained any ascertainable loss due to the delay.

      Moreover, Saul admitted the parties agreed to certain changes to the

contract but did not execute any written change orders, as required by N.J.A.C.

13:45A-16.2(a)(12). It is undisputed, however, that plaintiff performed the

                                                                        A-2418-18T2
                                       17
additional work. Defendants failed to show they sustained any ascertainable

loss because the additional work was not confirmed in written change orders.

      The record also shows that the Township inspector issued the notice of

violation, in part, because plaintiff removed the existing chimney without

obtaining a permit and failed to obtain a fire permit before it altered the

ventilation for the furnace.    Impink, acknowledged, however, that he had

approved the architect's plans for the project, which included an option to

remove the chimney.

      Impink nevertheless stated that a permit was required for removal of the

chimney but it was not uncommon for a contractor to obtain the permit after

completing the work. It is undisputed that plaintiff did not obtain the permit to

remove the chimney, or a fire permit for altering the ventilation for the furnace.

      Even so, plaintiff may have had a reasonable basis for assuming that,

because the Township had approved the plans and issued a permit for the work,

it did not need a permit to remove the chimney or change the ventilation of the

furnace. As noted previously, the trial court found that plaintiff should have

contested the Township's notice of violations.

      In any event, even if we assume that plaintiff violated N.J.A.C. 13:45A-

16.2(a)(10)(i) by failing to obtain all necessary permits for the work, defendants

                                                                          A-2418-18T2
                                       18
have not shown that they sustained an ascertainable loss causally related to the

violation. Zaman, 219 N.J. at 222. Defendants apparently spent $5800 to install

a new direct-vent furnace and water heater. However, plaintiff's failure to obtain

the necessary permits before removing the chimney does not bear a "causal

relationship" to the money defendants spent to install a new furnace and water

heater.

      Defendants assert that plaintiff created the venting problem by removing

the chimney and installing the temporary venting system. As the trial court

found, however, defendants never gave plaintiff an opportunity to correct and/or

cure the alleged deficiencies created by the removal of the chimney.

      Furthermore, defendants did not simply address the problem with the

temporary ventilation. They installed a new furnace and water heater. Thus,

defendants' expenditures were not causally related to plaintiff's failure to obtain

permits for removal of the chimney and the change in the ventilation system.

      We conclude the trial court did not err by dismissing defendant's CFA

claims with prejudice. There is sufficient credible evidence in the record to

support the court's finding that, even if plaintiff violated the HIP regulations,

defendants failed to show they sustained an ascertainable loss causally related

to the violations.

                                                                           A-2418-18T2
                                       19
      We note that defendants do not argue on appeal that the trial court erred

by dismissing their other claims. Thus, any claim that the trial court erred in

dismissing their claims is deemed to have been abandoned. El-Sioufi v. St.

Peter's Univ. Hosp., 382 N.J. Super. 145, 155 n.2 (App. Div. 2005) (noting that

an issue not briefed is deemed waived).

      Affirmed.

                                                                       A-2418-18T2
                                     20