Court Opinion

ID: 2746666
Source: CourtListenerOpinion
Date Created: 2014-10-29 22:03:06.093058+00
Date Added: 2024-06-11T09:53:54.073673
License: Public Domain

FILED
                                     2014 IL App (4th) 130824                   October 29, 2014
                                                                                  Carla Bender
                                           NO. 4-13-0824                       th
                                                                              4 District Appellate
                                                                                   Court, IL
                                  IN THE APPELLATE COURT

                                           OF ILLINOIS

                                       FOURTH DISTRICT

 R.L. VOLLINTINE CONSTRUCTION, INC., and                   )      Appeal from
 THE PEOPLE ex rel. R.L. VOLLINTINE CON-                   )      Circuit Court of
 STRUCTION, INC.,                                          )      Sangamon County
                Plaintiff-Appellant,                       )      No. 13MR536
                v.                                         )
 THE ILLINOIS CAPITAL DEVELOPMENT                          )
 BOARD; JIM UNDERWOOD, in His Official Capaci-             )
 ty as Executive Director of the Illinois Capital Devel-   )
 opment Board; THE OFFICE OF THE ARCHITECT                 )
 OF THE CAPITOL; and J. RICHARD ALSOP III, in              )      Honorable
 His Official Capacity as Architect of the Capitol,        )      Rudolph M. Brand,
                Defendants-Appellees.                      )      Judge Presiding.

               JUSTICE STEIGMANN delivered the judgment of the court, with opinion.
               Justices Turner and Holder White concurred in the judgment and opinion.

                                            OPINION

¶1             In September 2010, plaintiff, R.L. Vollintine Construction, Inc. (Vollintine), en-

tered into a construction contract with defendants, the Illinois Capital Development Board of the

State of Illinois; Jim Underwood, the Board's Director; the Office of the Architect of the Capitol;

and J. Richard Alsop III, the Architect of the Capitol (collectively, CDB).

¶2             In February 2011, during the term of the parties' contractual agreement, CDB

made a claim against Vollintine for water damage CDB alleged Vollintine caused. Vollintine

later sought payment for the contractual work it performed, which CDB postponed, pending res-

olution of its claim against Vollintine.

¶3             In June 2013, Vollintine filed a petition for writ of mandamus under article 14 of
the Code of Civil Procedure (Civil Code) (735 ILCS 5/14-101 to 14-109 (West 2012)), request-

ing that the court order CDB to submit to the State Comptroller the invoices Vollintine tendered

for the contractual work it completed and CDB approved. Vollintine also requested any statuto-

ry interest allowed under section 3-2 of the State Prompt Payment Act (Payment Act) (30 ILCS

540/3-2 (West 2012)).

¶4             In July 2013, CDB filed a motion to dismiss Vollintine's writ of mandamus pur-

suant to sections 2-619(a)(1) and 2-615(a) of the Civil Code (735 ILCS 5/2-619(a)(1), 2-615(a)

(West 2012)). CDB contended, in pertinent part, that the trial court lacked jurisdiction to consid-

er Vollintine's mandamus claim because section 8(b) of the Court of Claims Act (Claims Act)

grants the Court of Claims exclusive jurisdiction over "[a]ll claims against the State founded up-

on any contract entered into with the State" (705 ILCS 505/8(b) (West 2012)).

¶5             Following an August 2013 hearing, the trial court granted CDB's motion to dis-

miss, finding that the Court of Claims had exclusive jurisdiction over the parties' dispute.

¶6             Vollintine appeals, arguing that the trial court erred by granting CDB's motion to

dismiss. We disagree and affirm.

¶7                                      I. BACKGROUND

¶8             In September 2010, Vollintine entered into a construction contract with CDB to

fireproof structural steel in the western attic of the Illinois State Capitol building. The contract

required Vollintine to obtain a general-liability policy, which Pekin Insurance provided.

¶9             In February 2011, CDB sent Vollintine a letter, stating, in part, as follows:

                        "As you are aware, on January 13, 2011, a significant water

               leak occurred in the west wing of the Illinois Capitol as a result of

               a pipe failure. A 2 1/2[-inch] pipe separated from a coupling in the

                                                 -2-
               west attic causing water damage from the fourth floor to the se-

               cond floor. Several firms were retained by CDB to address the

               damage, all of which were observed by representatives of Pekin

               *** and Vollintine ***. To date, the State of Illinois has expended

               $315,632.73 to remediate damages.

                      The CDB believes the water leak occurred as a direct result

               of Vollintine's work associated with the [fireproofing] project.

               Therefore, CDB hereby makes a claim against Vollintine and Pe-

               kin *** to recoup all costs necessary to remedy the damages asso-

               ciated with the pipe failure."

¶ 10           From April to June 2011, Vollintine submitted three invoices to CDB, document-

ing expenses incurred as a result of the fireproofing work it performed. Later, in June 2011, Pe-

kin denied CDB's water-damage claim because (1) CDB did not provide any documentation to

support its allegation that Vollintine was responsible for the water damage and (2) Pekin's inter-

nal investigation did not support CDB's claim.

¶ 11           On January 6, 2012, Vollintine submitted its fourth invoice to CDB, which—

combined with its three previous invoices—sought $513,089 for its fireproofing services. On

January 11, 2012, CDB provided Vollintine a "certificate of substantial completion." The certif-

icate documented that on August 15, 2011, "all fireproofing in west attic and laylight" was

"complete." The certificate also provided, as follows:

               "Substantial completion and warranty time periods affected are de-

               fined in the General Conditions of the Contract. All parties listed

               below have reviewed the work under this contract and recommend

                                                 -3-
               issuance of the substantial completion. The [Office of the Archi-

               tect of the Capital] concurs with the CDB's acceptance and the

               [Architect/Engineer's] certification, will assume full possession

               and responsibility for the project or designated area, less punch[-]

               list items, on the above listed date. All warranties will start on the

               day of substantial completion, with the exception of those items on

               the punch list, which will start on the date of final acceptance.

               [Vollintine's] responsibility *** for heat, light, other utilities, and

               Builder's Risk Insurance required by the contract ceases at substan-

               tial completion. Other required insurance remains [Vollintine's]

               responsibility until the certificate of final acceptance is issued."

The certificate of substantial completion referred to an attached "punch list" that set forth 13

items that Vollintine was required to complete or correct by October 15, 2011.

¶ 12           The "General Conditions" portion of the parties' agreement provided, in pertinent

part, that after the certificate of substantial completion was issued, Vollintine was responsible for

coordinating the correction or completion of any punch-list items and, thereafter, informing CDB

that the contracted work is ready for final inspection. The agreement also provided that after

CDB issued the certificate of substantial completion, it could take possession of or use any por-

tion of the substantially completed area, but "[s]uch possession or use shall not be deemed ac-

ceptance of that part of the project being occupied, except as stated in the certificate, and shall

not constitute a waiver of existing claims by either party."

¶ 13           On August 21, 2012, the Office of the Attorney General for the State of Illinois

(AG) sent Vollintine a letter, in which it concluded that after a careful review, Vollintine was

                                                 -4-
responsible for the January 2011 water damage caused to the Capitol building. A listing append-

ed to the letter documented that the State spent $458,848 to repair the water damage as of that

date and estimated an additional $40,000 to $50,000 for restoration work yet to be contracted.

The AG informed Vollintine that in accordance with the provisions of the parties' construction

contract, once CDB determined the final amount of damages, it would withhold that amount

from its payment to Vollintine for the fireproofing work performed.

¶ 14           The parties' construction contract provided that "the contractor shall be responsi-

ble for all loss or damage to the work, the project, the site and improvements thereon, the work

of other contractors, and loss to CDB or the using agency including but not limited to costs of

suit, property damage, attorney fees, labor or costs of labor, caused by its performance of the

contract." A separate provision of the parties' agreement authorized CDB to withhold payment,

in whole or in part, if Vollintine was (1) not complying with the contractual terms, which includ-

ed the construction schedule; or (2) under investigation for failure to pay the prevailing-wage

rate.

¶ 15           On May 10, 2013, CDB sent a letter, informing Vollintine that the State spent

$511,990 to repair the damage incurred as a result of the January 2011 water leak, which CDB

concluded was caused by a Vollintine employee. CDB demanded that Vollintine provide com-

pensation for costs incurred to repair the water damage. CDB's letter also stated that "[a]s you

know, mediation on this matter is set for May 22, 2013." (The scheduled mediation was post-

poned after CDB discovered additional water damage.)

¶ 16           In June 2013, Vollintine filed a petition for writ of mandamus, requesting that the

court order CDB to submit to the State Comptroller the invoices Vollintine tendered for the fire-

proofing work it performed and CDB approved when it issued the certificate of substantial com-

                                               -5-
pletion. Vollintine also requested any statutory interest allowed under section 3-2 of the Pay-

ment Act.

¶ 17           In July 2013, CDB filed a motion to dismiss Vollintine's June 2013 writ of man-

damus under sections 2-619(a)(1) and 2-615(a) of the Civil Code. Specifically, CDB contended

that (1) the trial court lacked jurisdiction to consider Vollintine's mandamus claim because sec-

tion 8(b) of the Claims Act grants the Court of Claims exclusive jurisdiction over "[a]ll claims

against the State founded upon any contract entered into with the State" (705 ILCS 505/8(b)

(West 2012)), (2) Vollintine failed to state a cause of action for mandamus relief, (3) a writ of

mandamus is an inappropriate remedy, and (4) the Payment Act does not apply.

¶ 18           Following an August 2013 hearing, the trial court granted CDB's motion, finding

that the Court of Claims had exclusive jurisdiction over the parties' contractual dispute.

¶ 19           This appeal followed.

¶ 20                                      II. ANALYSIS

¶ 21           Vollintine argues that the trial court erred by granting CDB's section 2-619(a)(1)

motion to dismiss because the court incorrectly found that the Court of Claims had exclusive

subject-matter jurisdiction over the parties' dispute. We disagree.

¶ 22            A. A Section 2-619(a)(1) Motion To Dismiss and the Standard of Review

¶ 23           Section 2-619(a)(1) permits a trial court to dismiss a claim for lack of subject-

matter jurisdiction. 735 ILCS 5/2-619(a)(1) (West 2012). "In reviewing the grant of a section 2-

619 motion, we must interpret the pleadings and supporting materials in the light most favorable

to the plaintiff." Shirley v. Harmon, 405 Ill. App. 3d 86, 90, 933 N.E.2d 1225, 1228 (2010). We

review de novo a court's grant or denial of a motion to dismiss pursuant to section 2-619(a)(1) of

the Civil Code. Id., 933 N.E.2d at 1228-29.

                                                -6-
¶ 24                          B. The Pertinent Statutory Provisions

¶ 25           Prior to addressing the merits of Vollintine's argument, we first set forth the perti-

nent statutory provisions.

¶ 26           Section 1 of the State Lawsuit Immunity Act (Immunity Act) provides that

"[e]xcept as provided in the *** Claims Act *** the State of Illinois shall not be made a defend-

ant or party in any court." 745 ILCS 5/1 (West 2012).

¶ 27           The Claims Act created an exception to the doctrine of sovereign immunity under

section 1 of the Immunity Act by permitting parties to raise monetary claims against the State in

the Court of Claims. Lake v. State of Illinois, 401 Ill. App. 3d 350, 352, 928 N.E.2d 1251, 1254

(2010). The General Assembly—which established the conditions upon which monetary claims

against the state may be raised—determined that the Court of Claims should possess exclusive

subject-matter jurisdiction over such claims. Id. Both parties concede in their respective briefs

that section 8(b) of the Claims Act grants the Court of Claims exclusive jurisdiction to consider

"[a]ll claims against the State founded upon any contract entered into with the State." 705 ILCS

505/8(b) (West 2012).

¶ 28           Section 3-2 of the Payment Act provides, as follows:

               "Beginning July 1, 1993, in any instance where a State official or

               agency is late in payment of a vendor's bill or invoice for goods or

               services furnished to the State, as defined in Section 1, properly

               approved in accordance with rules promulgated under Section 3-3,

               the State official or agency shall pay interest to the vendor ***[.]"

               30 ILCS 540/3-2 (West 2012).

Section 3-3 of the Payment Act obligates the State Comptroller and Department of Central Man-

                                                -7-
agement Services to jointly publish rules and policies to govern the uniform application of the

Payment Act. 30 ILCS 540/3-3 (West 2012).

¶ 29                                    C. Vollintine's Claim

¶ 30           As previously discussed, Vollintine filed a petition for writ of mandamus in the

trial court, essentially requesting that the court order CDB to submit its invoices, totaling

$513,089, to the State Comptroller for payment. To properly frame Vollintine's argument, we

set forth the purpose and requirements of a petition for writ of mandamus, as follows:

                       " 'Mandamus relief is an extraordinary remedy to enforce,

               as a matter of right, the performance of official duties by a public

               official where the official is not exercising discretion. A court will

               not grant a writ of mandamus unless the petitioner can demonstrate

               a clear, affirmative right to relief, a clear duty of the official to act,

               and clear authority in the official to comply with the writ. The writ

               will not lie when its effect is to substitute the court's judgment or

               discretion for the official's judgment or discretion. Mandamus re-

               lief, therefore, is not appropriate to regulate a course of official

               conduct or to enforce the performance of official duties

               generally.' " Dye v. Pierce, 369 Ill. App. 3d 683, 686-87, 868
N.E.2d 293, 296 (2006) (quoting Hatch v. Szymanski, 325 Ill. App.
3d 736, 739, 759 N.E.2d 585, 588 (2001)).

¶ 31           Commensurate with the aforementioned requirements, Vollintine's overarching

claim is that the Payment Act imposed upon CDB a mandatory, nondiscretionary duty to submit

its invoices to the State Comptroller for payment. Vollintine's argument that the trial court erro-

                                                  -8-
neously determined that the Court of Claims had exclusive subject-matter jurisdiction proceeds

as follows.

¶ 32           Vollintine first contends, without legal citation, that the Payment Act creates "a

mandatory process by which a State vendor *** is ensured that the state promptly processes its

payment request or *** pay the vendor an interest penalty" for failure to do so. From that prem-

ise, Vollintine asserts that CDB's issuance of the certificate of substantial completion "triggered"

CBD's duty under the Payment Act to review and act upon the submitted invoices it tendered.

Vollintine then posits that the court's dismissal of its petition for writ of mandamus was errone-

ous because "[a] suit against state officials which seeks to compel them to perform their duty is

not held to be a suit against the state even though the duty to be performed arises under a certain

statute, and the payment of state funds may be compelled." In re Lawrence M., 172 Ill. 2d 523,

527, 670 N.E.2d 710, 713 (1996). Vollintine's claim is not persuasive.

¶ 33           We reject the notion that CDB's issuance of a certificate of substantial completion

created any duty under the Payment Act. As best we can tell, the phrase "certificate of substan-

tial completion" is a term of art that conveys a specific meaning to professionals in the construc-

tion trade. See Black's Law Dictionary 1511 (8th ed. 2004) (The phrase "term of art" is defined

as a term that has "a specific, precise meaning in a given specialty, apart from its general mean-

ing in ordinary contexts."). The plain language of the certificate of substantial completion that

CDB issued to Vollintine in January 2012 conveyed that as of August 15, 2011, Vollintine was

released from certain contractual obligations related to utilities and insurance, but Vollintine re-

mained responsible for items identified as requiring completion or correction, as well as main-

taining "other required insurance." In exchange, CDB assumed full possession and responsibility

for the western portion of the attic without either party relinquishing any contractual rights in so

                                                -9-
doing. The certificate of substantial completion did not address payment or the Payment Act,

but, instead, provided further guidance regarding obligations both parties had toward issuance of

a certificate of final completion.

¶ 34           More importantly, contrary to Vollintine's assertion, the Payment Act does not

impose a nondiscretionary duty upon CDB or any State agency to process payment vouchers

promptly, but, instead, confirms the procedure that the Court of Claim must adhere to if it deter-

mines that claimants are due payments from State agencies. See 30 ILCS 540/3-1 (West 2012)

("The Illinois Court of Claims shall, in its investigation of payments due claimants, provide for

interest penalties as prescribed in this Act ***.").

¶ 35           Our review of the plain language of the Payment Act evinces the legislature's in-

tent to encourage State agencies to promptly pay vendors for goods and services provided or be

subjected to further indebtedness in the form of interest penalties. The Payment Act does not, as

Vollintine contends, impose upon state agencies a mandatory, nondiscretionary duty to submit

invoices to the State Comptroller for payment after a certificate of substantial completion has

been issued. Indeed, the administrative rules and policies promulgated by the State Comptroller

and Department of Central Management Services governing the uniform application of the Pay-

ment Act mandate general and specific duties a state agency must satisfy, none of which support

Vollintine's claim or are relevant to this appeal. See 74 Ill. Adm. Code 900.30, 900.35, 900.40

(2002) (delineating general and specific duties state agencies must satisfy under the Payment

Act).

¶ 36           In this case, the facts clearly show a controversy between the parties regarding

payment for services rendered pursuant to a construction contract. Specifically, Vollintine has

requested payment from CDB for services rendered, and CDB has postponed payment because

                                                - 10 -
of the damages it incurred as a result of a water leak CDB claims Vollintine caused. Under these

undisputed facts, we agree with the trial court that the Court of Claims has exclusive jurisdiction

to adjudicate this litigation under section 8(b) of the Claims Act. Accordingly, we affirm the

court's judgment.

¶ 37                                  III. CONCLUSION

¶ 38           For the reasons stated, we affirm the trial court's judgment.

¶ 39           Affirmed.

                                               - 11 -