Court Opinion

ID: 2673315
Source: CourtListenerOpinion
Date Created: 2014-05-10 03:13:43.817938+00
Date Added: 2024-06-11T09:19:59.253001
License: Public Domain

In the United States Court of Federal Claims
                                         No. 12-245C

                                    (Filed: March 28, 2014)

**********************************                   Contract dispute; property acquisition and
                                             )       relocation contract entered to support
ROLLOCK COMPANY, et at.,                     )       creation of the Flight 93 National
                                             )       Memorial; claims under the Contract
                      Plaintiffs,            )       Disputes Act, 41 U.S.C. § 7104, and the
                                             )       Uniform Relocation Assistance and Real
       v.                                    )       Property Acquisition Policies Act, 42
                                             )       U.S.C. § 4622; jurisdiction; exhaustion of
UNITED STATES,                               )       administrative remedies; inchoate claims
                                             )       and contracting officer’s incipient
                      Defendant.             )       decisions; remand
                                             )
**********************************

       Irving M. Portnoy, Portnoy & Quinn, LLC, Pittsburgh, Pennsylvania, for plaintiff.

        Sarah M. Valenti, Trial Attorney, Commercial Litigation Branch, Civil Division, United
States Department of Justice, Washington, D.C., for defendant. With her on the briefs were
Stuart F. Delery, Assistant Attorney General, Bryant G. Snee, Acting Director, and Steven J.
Gillingham, Assistant Director, Commercial Litigation Branch, Civil Division, United States
Department of Justice, Washington, D.C. Of counsel was James Epstein, Office of the Northeast
Regional Solicitor, United States Department of the Interior.

                                    OPINION AND ORDER
LETTOW, Judge.

       The dispute in this case is over terms of a property acquisition and relocation contract
between the government and the plaintiffs, the Rollock Company, Anthony Kordell, and
Christopher Kordell (collectively “the Rollock plaintiffs” or “Rollock”). The National Park
Service (“NPS”) purchased land owned by the Rollock plaintiffs for the Flight 93 National
Memorial, land on which Rollock operated a scrap metal recycling facility. Compl. ¶¶ 2, 9. 1 In
contemplation of the land purchase, the contract between the parties provided for: (1) the sale of
business scrap inventory from Rollock to NPS and (2) a self-move of Rollock’s business
personal property, including embedded materials, to a new location. NPS agreed to pay Rollock
for monitoring costs associated with disposition of the scrap inventory NPS was purchasing and
       1
      Messrs. Kordell were the owners of the land, which had been leased to the Rollock
Company, and they were also officers and employees of the company. Compl. ¶¶ 7, 8.
removal of Rollock’s business personal property from the land. Rollock alleges that NPS
violated the terms of the contract by refusing to pay the full amount owed for the costs of
monitoring and of removal of Rollock’s business personal property. Compl. ¶¶ 28-29. Pending
before the court is the government’s Motion to Dismiss for Lack of Jurisdiction or, in the
Alternative, for Summary Judgment (“Def’s Mot.”), ECF No. 15. This motion has been fully
briefed, and a hearing was held on January 7, 2014.

                                       BACKGROUND 2

        In 2008, NPS approached the Rollock plaintiffs to discuss purchasing the property on
which Rollock’s scrap business was located, for the purpose of reconfiguring the property as part
of a memorial for the victims of Flight 93, which crashed as a result of terrorist acts on
September 11, 2001. See Pl.’s Br. in Opp’n to Def.’s Mot. (“Pl.’s Opp’n”) at 5, ECF No. 18; see
also Def.’s Mot. at 2. Between July 28, 2008 and July 17, 2009, NPS and Rollock negotiated an
agreement for the acquisition of the land and another agreement for the purchase of certain
materials and the relocation of Rollock’s business. See Def.’s App. A1-A50. 3 During this
discussion, NPS informed Rollock that relocation expenses would be covered by the government
in accordance with the Uniform Relocation Assistance and Real Property Acquisition Policies
Act (“Relocation Act”), Pub. L. 91-646, 89 Stat. 1894 (1971) (codified, as amended, at 42 U.S.C.
§ 4601-55), and its accompanying regulations found at 49 C.F.R. Part 24. See Def.’s App. A12
(Letter from Linda Beyer, NPS realty and relocation specialist, to Anthony and Christopher
Kordell and William Moot, Counsel (Jan. 26, 2009)). During the negotiations, Rollock notified
NPS that it considered materials embedded in the ground to be personal property of substantial
value and that it wished to reclaim this material as was customary for scrap metal operators.
Def.’s App. A15-16 (Letter from Moot to Beyer (Feb. 18, 2009)). 4 NPS agreed that embedded
materials should be considered personal property and included in the relocation process, Def.’s
App. A24 (Letter from Robert Merryman, O.R. Colan Assocs., to Moot (Mar. 26, 2009)), and
further advised Rollock that it had the “right to have professional services performed to assist
with [the] move” but that “[a]ny professional services needed will require advanced approval
from [NPS] before fees can be authorized.” Def.’s App. A21 (Letter from Beyer to Moot (Mar.
31, 2009)).

       As a result of these negotiations, NPS prepared and transmitted a “Draft Proposed
Relocation Agreement” on July 17, 2009. Def.’s App. A34. This agreement was executed by
Rollock on August 25, 2009 and by NPS on August 27, 2009. Def.’s App. A58-78 (“Relocation

       2
        The recitation of circumstances which follows does not constitute findings of fact by the
court and is given solely to provide a context for deciding the pending motion. Disputes of fact
are noted.
       3
        For convenience, the court will cite the extensive appendix to the government’s Motion
to Dismiss using the designation “Def.’s App. __” and referring to pages within the sequential
pagination of documents contained in the appendix.
       4
        This material included both magnetic and non-magnetic material of financial value to
Rollock. Def.’s App. A15.

                                                2
Agreement” or “Agreement”). NPS agreed to purchase Rollock Company’s stockpiled business
scrap inventory for $1,812,000.00, a scale for $65,000.00, and stockpiled topsoil for
$290,192.00. Def.’s App. A58-59. NPS also agreed to provide self-move relocation costs for
Rollock’s embedded material inventory based on 49 C.F.R. 24.301(d)(2)(i). 5 Def.’s App. A59. 6
The parties agreed that NPS would excavate the embedded material and place it in stockpiles at
the Rollock site. Id. Rollock would then remove the stockpiles and transport them to a new
location within 50 miles of the Rollock site. Id. The timeline provided in the Agreement stated
that NPS would excavate the embedded material within sixty days from the disposition of the
business scrap inventory NPS was purchasing and that Rollock would remove the resulting
stockpiles within thirty days after NPS notified it that the stockpiles were completed. Id.

        Because the transfer of the business scrap and the removal of the embedded material was
to take place over a period of months, Rollock would require personnel to monitor the site. In
the “business scrap inventory” section of the Agreement, the contract provided reimbursement
for these monitoring costs, stating that

       Rollock will be reimbursed for related costs paid to any persons to monitor the progress
       of the sale by NPS, or their contractor, of the [business scrap inventory] and the removal
       of the [embedded material]. The cost of said reimbursement will be at a pre-determined
       rate agreed to by NPS and Rollock[,] which rate will be the actual documented rate paid
       for such monitoring personnel.

Def.’s App. A59. NPS and Rollock later confirmed that the rate for the monitor at the Rollock
site would be $60.00 per hour. See Def.’s App. A86 (Letter from Moot to Beyer (Oct. 19,
2009)); Def.’s Mot. at 7; Pl.’s Opp’n at 8.

                                        A. Monitoring Costs

         NPS acquired title to the Rollock site on September 23, 2009. Pl.’s Opp’n at 7.
Thereafter, Rollock began submitting claims to NPS for reimbursement of monitoring costs. The
first claim submitted totaled $15,840.00 and covered the period from October 14, 2009 to
November 24, 2009. Def.’s App. A87. This claim was calculated at the rate of $60.00 per hour
with overtime at $90.00 per hour. Id. With its claim, Rollock submitted an affidavit by Anthony
Kordell certifying the hours worked by the monitor. Def.’s App. A87. On December 10, 2009,
NPS, without requiring additional documentation from Rollock, approved the claim. See Def.’s
App. A92. Rollock continued to submit claims for monitoring in the same manner, i.e., with an

       5
         The regulation provides that payment for a self-move by a business may be based on
“[t]he lower of two bids or estimates prepared by a commercial mover or qualified [a]gency staff
person. At the [a]gency’s discretion, payment for a low cost or uncomplicated move may be
based on a single bid or estimate.” 49 C.F.R 24.301(d)(2)(i).
       6
        Under the terms of the Agreement, embedded material covered “subterranean scrap
material found under the [business scrap inventory] piles . . . and is defined as the scrap material
located within [one] foot of the surface under each [business scrap inventory] pile.” Def.’s App.
A59.

                                                 3
affidavit certifying hours worked by the monitor and at the hourly rate of $60.00 with overtime
calculated at $90.00 per hour. Pl.’s Opp’n at 8; see also Def.’s Mot. at 8. Between March 29,
2010 and May 5, 2010, Rollock submitted three additional claims for monitoring that took place
between November 25, 2009 and April 27, 2010. Pl.’s Opp’n at 8; Def.’s Mot. at 8. 7 On March
31, 2010, Rollock submitted to NPS a letter outlining concerns it had regarding progress on
removal and payment for the business scrap inventory, recovery of the embedded material, and
payment for the outstanding claims for monitoring costs. Def.’s App. A112-117 (Letter from
Moot to Anthony Conte, NPS Regional Solicitor (Mar. 31, 2010)).

        On June 18, 2010, NPS notified the Rollock plaintiffs that “to process payment for the
monitor[,] the NPS must have receipted evidence of payment to the employee and timesheets.”
Def.’s App. A120 (Letter from Conte to Moot (June 18, 2010)). In response, on June 25, 2010,
Rollock submitted canceled checks issued to the monitor dating from October 30, 2009 to May
28, 2010. Def.’s App. A121, A134-49. Rollock also submitted an additional claim of
$12,660.00 for monitoring between April 28, 2010 to May 25, 2010, bringing the total unpaid
claim amount to $69,465.00. Def.’s App. A127. 8 The documents that Rollock submitted
showed that the monitor was being paid an hourly rate of $40.00 with overtime calculated at
$60.00 per hour. Def.’s App. A157. On July 9, 2010, NPS responded to the Rollock plaintiffs to
advise them that it considered the total reimbursable costs for the monitor to be the actual
expense paid by Rollock to the monitor, calculated at $40.00 of regular pay per hour, rather than
the earlier agreed rate of $60.00 per hour. Def.’s App. A159 (Letter from Beyer to Moot (July 9,
2010)). NPS determined that it owed Rollock a total of $29,108.39, the difference between the
total monitoring expense of $44,948.39 actually paid to the monitor less $15,840.00 already paid
by NPS to Rollock. Id. Rollock responded on July 14, 2010, stating that it believed the contract
indicated that the proper reimbursement amount should be calculated based on $60.00 per hour
and that the actual wages of $40.00 per hour did not adequately cover the costs to the company
for employing the monitor. Def.’s App. A161 (Letter from Moot to Beyer (July 14, 2010)). 9
NPS disagreed; on July 14, 2010, it paid Rollock $29,108.39, reflecting the total it believed was
due to Rollock. Def.’s App. A165. 10

       7
         The first claim sought $26,565.00 for November 25, 2009 through February 2, 2010, the
second claim requested $18,180.00 for the period of February 3, 2010 to March 16, 2010, and
the third claim sought $12,060.00 for March 17, 2010 to April 27, 2010. Def.’s App. at A104,
A110, A119.
       8
        This additional claim was also calculated at an hourly rate of $60.00 with overtime at
$90.00 per hour. Def.’s App. A127.
       9
         Although a spreadsheet appears on Def.’s App. A157 summarizing Rollock’s indirect
employee costs, encompassing payments for such things as social security and Medicare taxes,
unemployment insurance, accident insurance premiums, and health care premiums, NPS appears
to have failed to consider the relevance of these indirect costs.
       10
        NPS informed Rollock that claims for reimbursement required documentation of
payments and audit sheets, Def.’s App. A165, which Rollock provided on August 9, 2010, Def.’s
App. A170.

                                                4
        On September 7, 2010, NPS informed Rollock that it was “not obligated to pay . . .
monitoring costs beyond June 24, 2010” because, according to NPS, stockpiling of embedded
material ended on June 24, 2010, despite the fact that an additional 1.8 acres still needed to be
scraped. Def.’s App. A211 (Letter from Conte to Moot (Sept. 7, 2010)) (“While we realize now
that approximately 1.8 acres has not been completed, for all intents and purposes, a monitor will
not be necessary until the new permits arrive and NPS schedules the scraping of the remainder of
the embedded material.”). On September 22, 2010, NPS determined it owed Rollock an
additional $16,722.00 for monitoring costs, reflecting a total reimbursable amount of $61,670.00
for monitoring through May 25, 2010. Def.’s App. A215 (Letter from Beyer to Moot (Sept. 22,
2010)). NPS also stated that Rollock could submit additional reimbursement claims for
monitoring costs occurring between May 26, 2010 and June 24, 2010, acknowledging also that
Rollock could incur additional monitoring costs for the scraping of the remaining 1.8 acres. Id.
On November 23, 2010, NPS clarified its position on monitoring reimbursement, indicating that
due to delays in securing necessary permits, no monitoring was necessary from June 24, 2010
until scraping of the remaining 1.8 acres began. Def.’s App. A230 (Letter from Beyer to Moot
(Nov. 23, 2010)); see also Def.’s App. A229 (e-mail from Beyer (Nov. 3, 2010)).

        Rollock responded to NPS, disagreeing with NPS’s conclusion that monitoring was not
needed after June 24, 2010. Def.’s App. A231 (Letter from Moot to Beyer (Dec. 2, 2010)).
Rollock interpreted the Agreement to require monitoring until all the embedded material was
removed, and because this condition had not been met, Rollock believed that NPS was still
obligated to pay monitoring costs. Id. Accordingly, Rollock submitted a claim totaling
$76,305.00 for monitoring costs between May 26, 2010 through November 23, 2010 at the
hourly rate of $60.00 with overtime at $90.00 per hour. See id. 11 NPS responded on December
20, 2010, that it had determined $8,110.00 was reimbursable for monitoring between May 26,
2010 and June 22, 2010 and denied the remaining amounts claimed. Def.’s App. A245 (Letter
from Beyer to Moot (Dec. 20, 2010)). NPS reiterated that monitoring was not required until
permits were obtained and then “[a]ctual monitoring expenses for [removal activity] can be
submitted for reimbursement.” Id. NPS advised that Rollock had the right to appeal the denial
of this most recent claim for reimbursement via written appeal within 60 days to the Department
of the Interior, Office of the Director, Office of Hearing and Appeals. Id. NPS did not include
any statutory or regulatory citations that might identify and clarify the appeals process. See Pl.’s
Opp’n at 11; see also Def.’s App. A245. Rollock did not file an appeal with the Office of
Hearing and Appeals. Def.’s Mot. at 10. Instead, Rollock responded with a letter reiterating its
arguments for reimbursement for the total monitoring costs claimed and indicating that it
believed the Contract Disputes Act, 41 U.S.C. §§ 7101-09, should govern the dispute. Def.’s

         NPS sent a proposed amendment to the Agreement on July 28, 2010. Def.’s App. A166.
The proposed amendment would have set reimbursement for monitoring costs at $60.00 per
hour, required Rollock to provide NPS with cancelled checks and payroll pay stubs, and
provided an end date to monitoring on July 30, 2010. Def.’s App. A167. The amendment was
never executed. See Pl.’s Opp’n at 10 n.3.
       11
         Rollock asserted that the amount paid by NPS for monitoring through May 25, 2010
was insufficient and “d[id] not accept the prior payments as ‘payment in full.’” Def.’s App.
A231.

                                                 5
App. A247 (Letter from Moot to Beyer (Feb. 18, 2011)). NPS replied with “a final response,”
repeating its arguments that monitoring was not necessary after June 24, 2010. Def.’s App.
A248 (Letter from Beyer to Moot (Mar. 15, 2011)). After NPS’s “final response,” Rollock
continued to monitor the movement of embedded material and to submit claims for both
monitoring and relocation costs, and NPS paid portions of these further claims. Def.’s App.
A249-373. Movement of material and monitoring may have ceased in October 2011. Def.’s
App. A362 (Letter from William Sindelar, NPS Land Acquisition Officer, to Moot (Oct. 6,
2011)). To date, Rollock has submitted claims for monitoring costs totaling $286,321.00; of this
amount, $69,780.39 12 appears to have been paid by NPS. Pl.’s Opp’n at 12.

                                      B. Embedded Materials

         On May 17, 2011, NPS notified Rollock that the embedded material inventory had been
stockpiled and was ready to be removed from the site. Def.’s App. A249 (Letter from Sindelar
to Moot (May 17, 2011)). NPS also included information regarding a bid it had received for the
loading and hauling of the embedded material, totaling $635,000.00 for an approximate volume
of 19,037 cubic yards of stockpiled embedded material. Def.’s App. A249-54. Using this bid as
its reference, NPS determined that the “total reimbursable payment due upon completion of this
self-move of the [s]tockpiled [e]mbedded [m]aterial will be $635,000.00.” Id. Rollock
responded on May 19, 2011, requesting an advance relocation payment, similar to advance
payments made by NPS for earlier self-moves of Rollock’s personal property. Def.’s App. A259
(Letter from Moot to Sindelar (May 19, 2011)). NPS denied Rollock’s request for an advance
because the program was “a reimbursable program” that did not allow payment for costs not yet
incurred. Def.’s App. A274 (Letter from Sindelar to Moot (June 22, 2011)). NPS did confirm
that it “would consider partial payments paid directly to a contractor provided [it] had a valid
contract to move the [s]tockpiled [e]mbedded [m]aterial.” Id. 13

        On June 20, 2011, Rollock sold to Kinsley Construction, Inc. (“Kinsley”) approximately
4,500 cubic yards of topsoil 14 which was stockpiled at the Rollock site, for a total price of one
dollar. Def.’s App. A294 (Letter from Greg Martz, Kinsley Construction Project Manager, to

       12
          Rollock states that NPS provided reimbursement totaling $44,949.39 for the monitoring
costs, but the documentary materials provided indicate that $69,780.39 was actually paid. See
Def.’s App. A92 ($15,840.00 payment voucher signed Dec. 10, 2009), A154 ($29,108.39
payment approved on July 12, 2010). A219 ($16,722.00 payment voucher signed Oct. 4, 2010),
A245 ($8,110.00 payment voucher signed Dec. 20, 2010).
       13
          NPS had previously indicated that 49 C.F.R. § 24.207(c) would permit an advanced
relocation payment if Rollock could demonstrate a need for one and submit a self-move claim
for the relocation. See Def.’s App. A260 (letter from Sindelar to Moot (May 25, 2011)).
Rollock submitted the relevant documentation, Def.’s App. A262, but NPS did not approve the
advance. Def.’s App. A274.
       14
         The government characterizes this topsoil as “non-co[n]taminated dirt from the
[s]tockpiled [e]mbedded [m]aterial pile.” Def.’s App. A288.

                                                 6
Moot (June 20, 2011)); Hr’g Tr. 26:5 to 27:20, 28:7-11 (Jan. 7, 2014). 15 The “topsoil” was dirt
that had been accumulated during the process of scraping and removing the embedded material.
Hr’g Tr. 26:5 to 27:20. Kinsley paid Rollock and removed the topsoil from the site before the
end of June. See Def.’s App. A288 (e-mail from Sindelar (June 20, 2011)). 16 Kinsley reportedly
was the government’s contractor to prepare the Flight 93 site for the memorial, and it apparently
wanted the dirt as fill in leveling the ground. Hr’g Tr. 27:1-7.

       On June 27, 2011, Rollock hired Military Resource Enhancement Specialists, Inc.
(“MRES”) to move the stockpiled embedded material. The contract specified relocation of an
estimated 19,037 cubic yards of material for $635,000.00. Def.’s App. A280 (Agreement
between Rollock and MRES (June 27, 2011)). Rollock informed NPS of the contract with
MRES, Def.’s App. A276 (Letter from Moot to Sindelar (June 28, 2011)), but not of the contract
with Kinsley, see Def.’s App. A276, A288. Rollock also filed a claim with NPS seeking an
advance payment of half of the contract relocation price, $317,500.00. Def.’s App. A276. NPS
denied Rollock’s claim for an advance payment, citing a need for documentation that MRES had
begun the relocation process, and it also informed Rollock of its awareness of the topsoil sale to
Kinsley. Def.’s App. A289 (Letter from Sindelar to Moot (July 5, 2011)). NPS advised that it
would reduce the self-move reimbursement to reflect the volume of topsoil sold to Kinsley. Id.
Shortly thereafter, Rollock responded by indicating that half of the stockpiled material had been
moved and asking that payment be made. Def.’s App. A292 (Letter from Moot to Sindelar (July
7, 2011)). NPS took the position that because the topsoil was owned by Kinsley rather than by
Rollock at the time of relocation, Rollock could not seek relocation costs for that material.
Def.’s App. A295 (Letter from Sindelar to Moot (July 15, 2011)). As with the denial of
monitoring costs, NPS informed Rollock of its right to appeal the decision within 60 days to the
Department of the Interior’s Office of Hearings and Appeals. Id. 17

         NPS revised the relocation amount to $451,541.48, 18 reflecting a reduction for the
volume of topsoil removed by Kinsley. Def.’s App. A306 (Letter from Sindelar to Moot (Aug.
5, 2011)). Through a series of four payments, each for a quarter of the reduced amount, NPS
approved and Rollock received $451,541.48, the complete amount of NPS’s reduced total.
Def.’s Mot. at 7; Pl.’s Opp’n at 18. Rollock consistently stated that it believed it was entitled to
the full amount of $635,000.00, Def.’s App. A297, and that it “d[id] not agree with the reduction

       15
          References to the date of the hearing will be omitted in further citations to the hearing
transcript.
       16
          The purchase and sale agreement for the topsoil was embodied in a one-page letter that
stated that Kingsley “shall take possession of the [t]opsoil and remove the [t]opsoil from [the
Rollock site] as soon as possible.” Def.’s App. A294.
       17
         Again, NPS did not provide any citations to statutes or regulations to explain the
appeals process. Pl.’s Opp’n at 16; see also Def.’s App. A295.
       18
          Originally, NPS reduced the total to $484,879.57 but subsequently revised this amount
to reflect a more accurate calculation of the material moved by MRES. See Def.’s App. A295,
A306.

                                                  7
in the price,” Def.’s App. A320, A343, A349. Rollock uniformly certified its claims on the
form provided by NPS to make a “Claim for Relocation Payments – Nonresidential.” See, e.g.,
Def.’s App. A322, A340, A349. With each payment, NPS notified Rollock of its right to appeal
the decision within 60 days to the Department of Interior’s Office of Hearings and Appeals. See
Def.’s App. A306-07, A337, A361-62. No such appeals were filed.

                                    STANDARDS FOR DECISION

        To bring claims before the court, the plaintiff must plausibly allege sufficient facts to
show the court’s subject matter jurisdiction over each claim. McAfee, Inc. v. United States, 111
Fed. Cl. 696, 706 (2013) (citing McNutt v. General Motors Acceptance Corp of Ind., 298 U.S.
178, 189 (1936)). When considering a motion to dismiss for lack of subject matter jurisdiction
under Rule 12(b)(1) of the Rules of the Court of Federal Claims (“RCFC”), unchallenged factual
allegations in the complaint will be construed in favor of the pleader, but any disputed
jurisdictional facts must be shown by a preponderance of the evidence. Id. The court may look
beyond the pleadings and inquire into jurisdictional facts. See Rocovich v. United States, 933 F.2d
991, 993 (Fed. Cir. 1991).

       As an alternative to dismissal under RCFC 12(b)(1), the government has moved for
summary judgment under RCFC 56. RCFC 56(a) provides that “[t]he court shall grant summary
judgment if the movant shows that there is no genuine dispute as to any material fact and the
movant is entitled to judgment as a matter of law.” The moving party bears the initial burden of
demonstrating the absence of any genuine issue of material fact. Celotex Corp. v. Catrett, 477
U.S. 317, 323 (1986). A fact is material if it is one “that might affect the outcome of the suit
under the governing law.” Anderson v. Liberty Lobby, Inc., 477 U.S. 242, 248 (1986). A
genuine dispute is one that “may reasonably be resolved in favor of either party.” Id. at 250.

                                           ANALYSIS

                  A. The Statutes Underpinning Rollock’s Contractual Claims

        The Tucker Act, 28 U.S.C. § 1491(a), grants this court jurisdiction over disputes arising
under contracts with the federal government. In pertinent part, the Tucker Act provides that
“[t]he United States Court of Federal Claims shall have jurisdiction to render judgment upon any
claim against the United States founded . . . upon any express or implied contract with the United
States.” 28 U.S.C. § 1491(a)(1). To support jurisdiction over its claims, Rollock additionally
invokes the Contract Disputes Act (“CDA”), 41 U.S.C. § 7104(b), which allows a contractor to
challenge a decision by a federal contracting officer denying a claim under certain contracts by
bringing an “action directly on the claim in the United States Court of Federal Claims.” 41
U.S.C. § 7104(b)(1). The Tucker Act expressly recognizes this grant of jurisdiction and states,
“[t]he Court of Federal Claims shall have jurisdiction to render judgment upon any claim by or
against, or dispute with, a contractor arising under section 7104(b)(1) of title 41.” 28 U.S.C.
§ 1491(a)(2).

        The CDA applies to “any express or implied contract . . . made by an executive agency
for – (1) the procurement of property, other than real property in being; (2) the procurement of
services; (3) the procurement of construction, alteration, repair, or maintenance of real property;

                                                 8
or (4) the disposal of personal property.” 41 U.S.C. § 7102. Rollock concedes that it had a
contract with NPS for the purchase of real property, which is excluded from the CDA’s scope.
Pl.’s Opp’n at 22-23. It contends, however, that this case turns on the contemporaneously
executed Relocation Agreement, which addressed the procurement of personal property, the
provision of monitoring services, and the alteration of real property by removal of personal
property, and calls for application of the CDA to all of the claims at issue. Id. at 24.

        The government disagrees that the CDA applies and contends that the Relocation Act is
the appropriate basis for Rollock’s claims for money damages. Def.’s Reply to Pl.’s Opp’n
(“Def.’s Reply”) at 4-8, ECF No. 19. Congress created the Relocation Act to establish a
“[u]niform policy on real property acquisition practices.” 42 U.S.C. § 4651 (heading). As a
general matter, the Relocation Act provides federal agencies with a process for negotiating the
purchase of private property for public use. See 42 U.S.C. § 4651. In connection with federal
purchases or condemnation of real property, the Act sought to provide “relocation assistance
policies . . . for fair, uniform, and equitable treatment of all affected persons.” 42 U.S.C.
§ 4621(a)(2). The relocation assistance authorized to be provided encompasses, among other
things, “actual reasonable expenses in moving [the displaced person], his family, business, farm
operation, or other personal property.” 42 U.S.C. § 4622(a)(1). In recognition that
disagreements might arise, the Relocation Act provides a general outline of procedures to be
used in resolving disputes over relocation assistance. Section 213 of the Act, as amended by
Pub. L. 100-17, § 412, 101 Stat. 132, 254-55 (1987), provides in pertinent part that:

       The head of the lead agency is authorized to issue such regulations and establish such
       procedures as he may determine to be necessary to assure –

       ...

       (2) that a displaced person who makes proper application for a payment authorized for
       such person by this subchapter shall be paid promptly after a move or, in hardship cases,
       be paid in advance;

       (3) that any aggrieved person may have his application reviewed by the head of the
       Federal agency having authority over the applicable program or project.

42 U.S.C. § 4633(b) (emphasis added). The “lead agency” is defined as the Department of
Transportation. 42 U.S.C. § 4601(12).

      The Department of Transportation, acting under the authority of Section 213, has
promulgated implementing regulations found in 49 C.F.R. Part 24. 19 Among other things, these

       19
          The Department Transportation established these regulations in 1987 as “a single
government[-]wide rule codified in one instead of 17 places in the Code of Federal Regulations.”
Uniform Relocation Assistance and Real Property Acquisition Regulation for Federal and
Federally Assisted Programs, 52 Fed. Reg. 47,994, 48,105 (Dec. 17, 1987) (codified at 49 C.F.R.
Part 24). The Department of Transportation’s regulation was to replace agency specific
codifications of a government-wide verbatim common rule. The Department of the Interior was

                                                9
regulations establish general requirements for relocation payments, 49 C.F.R. § 24.207,
including payments for moving and related expenses, 49 C.F.R. §§ 24.301-.306. A person who
contends that the acquiring agency “has failed to properly consider the person’s application for
assistance . . . includ[ing] . . . a relocation payment under this part” may file a written “appeal”
with the acquiring agency. 49 C.F.R. § 24.10(b). After the agency reaches a decision on the
appeal, and “[i]f the full relief requested is not granted, the [a]gency shall advise the person of
his or her right to seek judicial review of the [a]gency decision.” 49 C.F.R. § 24.10(g). This
regulation also addresses the timing of an appeal and the right of a person to representation and
to inspect relevant materials. 49 C.F.R. § 24.10(c), (d), (e).

                                     B. Applicability of the CDA

         In support of its argument that the CDA serves as the basis for all of its claims, Rollock
cites to Bonneville Assocs. v. United States, 30 Fed. Cl. 85 (1993), as support for the contention
that the CDA may apply to a dual-purpose contract where one purpose is covered under the CDA
but another purpose is not. See Pl.’s Opp’n at 22. This reading of Bonneville Associates is
correct, but Rollock only gets partial help from this decision. While the court in Bonneville
Associates did ultimately apply the CDA’s provisions, it did so only to part of the contract. The
court determined that dual elements of the contract were sufficiently distinct that it could apply
the CDA to one aspect of the contract without concerning the other. See Bonneville Assocs., 30
Fed. Cl. at 88. Thus, Bonneville Associates informs that claims under a dual-purpose contract
may be severable and that different statutes may apply to claims arising from such a contract.
Here, Rollock brings separate claims, one for monitoring costs and another for relocation costs
for embedded materials, see Compl. ¶¶ 21, 28-29, and these claims can and do have different
statutory predicates.

        Based on the terms of the Agreement, the monitor was responsible to oversee (1) the sale
of business scrap inventory from Rollock to NPS and (2) the removal of the embedded material
from the Rollock site. Def.’s App. A59. The removal of the embedded material did not begin
until after the sale to the government of the business scrap inventory. Id. Therefore, costs
associated with the monitor pertain both to the government’s purchase of Rollock’s scrap
inventory and to the removal of Rollock’s personal property, specifically the embedded
material. 20 The purchase by NPS of the business scrap inventory is manifestly a procurement

one of the agencies directed to remove its own regulation even though that regulation only
referred to the Department of Transportation’s regulations. Id. at 48,024. In the 1988 and 1989
editions of the Code of Federal Regulations, Interior’s regulations included a cross-reference to
the regulations found in 49 C.F.R. Part 24. See 41 C.F.R. § 114-50.301-1 (1988); 41 C.F.R.
§ 114-50.301-1 (1989). This cross-reference has since disappeared from Interior’s regulations.
          In all events, the government emphasizes that the Department of Transportation’s
regulations reach “[g]overnment-wide,” applying to all federal departments and agencies,
including the Department of the Interior. Def.’s Mot. at 15.
       20
         As noted earlier, the CDA governs a contract for procurement of personal property by
an executive agency. 41 U.S.C. § 7102. “‘Procurement’ [in the CDA] is ‘the acquisition by
purchase, lease or barter, of property or services for the direct benefit or use of the [f]ederal

                                                 10
under the CDA. As a result, the portion of the monitoring costs associated with overseeing the
sale of the business scrap inventory is properly governed by the CDA.

        The removal and relocation of the embedded material is a different matter. Rollock
argues that the relocation of embedded material is an “alteration of real property” within the
meaning of the CDA. Pl.’s Opp’n at 22-23 (referring to a portion of the applicability delineation
in 41 U.S.C. § 7102(3) of contracts to which the CDA applies). The purpose of removing the
embedded material, however, was to enable Rollock to relocate its personal property. Any
alterations in the Rollock site were secondary to achieving this purpose. This is evidenced by
NPS’s original offer omitting any reference to embedded materials and Rollock’s insistence that
embedded materials should be included in the Agreement. See Def.’s App. A15-16; see also
Pl.’s Opp’n at 12-13. In short, recovery and removal of the embedded material is attendant to a
move of personal property as a result of the government’s acquisition of land and therefore falls
under the Relocation Act. Indeed, the Agreement specified that the self-move of the embedded
materials was governed by regulations under the Relocation Act, 49 C.F.R. § 24.301(d)(2)(i).
See Def.’s App. A59. Consequently, the monitoring costs associated with the removal and
relocation of the embedded material are also governed by the Relocation Act rather than the
CDA.

        Nonetheless, Rollock avers that “there is no conflict between the CDA and the
[Relocation] Act and, in fact, that the CDA is the only appropriate way to bring a breach of
contract claim against the United States.” Pl.’s Opp’n at 26 (citing Zoeller v. United States, 65
Fed. Cl. 449, 459-60 (2005)). In Zoeller, the plaintiff had leased parcels of land from the
government at Fort Leavenworth, Kansas, and brought suit alleging claims under the CDA and
the Relocation Act for the government’s partial termination of a lease on several of the parcels.
65 Fed. Cl. at 452. The plaintiff alleged, in part, that he “suffered a compensable taking when
the government did not follow certain guidelines outlined in section 4651 of [title 42, part of the
Relocation Act],” which sets out “[u]niform policy on real property acquisition practices,” 42
U.S.C. § 4651 (heading). Zoeller, 65 Fed. Cl. at 452. The court determined that plaintiff could
not recover because (1) he was not a landowner and therefore not covered by the Relocation Act,
(2) the Relocation Act does not mandate money damages for failure to comply with the
provisions provided in Section 4651, and (3) judicial review of an agency’s actions under
Section 4651 is foreclosed by 42 U.S.C. § 4602, which explicitly provides that Section 4651
“create[s] no rights or liabilities and shall not affect the validity of any property acquisitions by
purchases or condemnation. See Zoeller, 65 Fed. Cl. at 459-60. Rollock argues that although the
court dismissed the Zoeller claims, its analysis under both the CDA and the Relocation Act
indicates that there is no conflict between the two statutes and a plaintiff may choose to file
claims under either one or the other. Pl.’s Opp’n at 28. As the government points out, however,
this argument fails to consider that the lease of real property in Zoeller was governed by the
CDA. See Def.’s Reply at 5 (citing Forman v. United States, 767 F.2d 875, 878-79 (Fed. Cir.
1985) (holding that leases from the government are contracts subject to the CDA)). The

[g]overnment.’” Wesleyan Co., Inc. v. Harvey, 454 F.3d 1375, 1378 (Fed. Cir. 2006) (emphasis
in the original) (quoting New Era Constr. v. United States, 890 F.2d 1152, 1157 (Fed. Cir.
1989)).

                                                 11
Relocation Act is applicable to acquisition by the government of a landowner’s real property, see
Zoeller, 65 Fed. Cl. at 459, but the CDA is not.

        Additionally, the court’s observations in Zoeller regarding the justiciability of Section
4651 of the Relocation Act are irrelevant to the case at hand because Rollock is not relying on
Section 4651 as a basis for money damages. Any such reliance would have been unavailing.
The provisions of 42 U.S.C. § 4602 explicitly bar reliance on the policies set out in Section 4651
as a basis for monetary claims. See also Delancey v. City of Austin, 570 F.3d 590, 593-95 (5th
Cir. 2009) (holding that policy provisions of the Relocation Act do not create any private rights
of action for money damages, applying the factors enunciated in Gonzaga University v. Doe, 536
U.S. 273, 280 (2002)). In Zoeller, the plaintiff relied on general guidelines provided in the
Relocation Act. Zoeller, 65 Fed. Cl. at 452. Because these guidelines were not enforceable by
money damages and were not subject to judicial review, the plaintiff could not recover. Id. at
459-60. Contrastingly, the provision of the Relocation Act upon which Rollock relies
specifically provides for payment by an agency of moving costs wholly apart from the CDA, see
42 U.S.C. § 4622(a)(1), and disputes over such payments can be considered by courts, see Pou
Pacheco v. Soler Aquino, 833 F.2d 392 (1st Cir. 1987); Tullock v. State Highway Comm’n, 507
F.2d 712, 715 (8th Cir. 1974).

                           C. Prerequisites for a Claim under the CDA

        For the court to exercise jurisdiction over a claim made under the CDA, the contractor
must first submit a written claim to the contracting officer and the contracting officer must issue
a final decision on the claim. Northrup Grumman Computing Sys., Inc. v. United States, 709
F.3d 1107, 1110-12 (Fed. Cir. 2013); Rex Sys., Inc. v. Cohen, 224 F.3d 1367, 1372 (Fed. Cir.
2000). A claim under the CDA must be “(1) a written demand or assertion, (2) seeking as a
matter of right, (3) the payment of money in a sum certain.” James M. Ellett Constr. Co. v.
United States, 93 F.3d 1537, 1542 (Fed. Cir. 1996). The claims need not take any specific form
as long as they provide the contracting officer with adequate notice of the basis and the amount
of the claims. Northrup Grumman, 709 F.3d at 1112-13; Contract Cleaning Maint., Inc. v.
United States, 811 F.2d 586, 592-93 (Fed. Cir. 1987). For a claim over $100,000, the contractor
must certify the claim in accordance with 41 U.S.C. § 7103(b)(1).

        The government argues that Rollock failed to satisfy these requirements because the
submission of claims to Ms. Beyer, Mr. Sindelar, and Mr. Conte do not satisfy the requirement
of a submission to a contracting officer. Def.’s Reply at 6-7. There are a number of problems
with the government’s contention. First, the government has failed to name the appropriate
person with whom Rollock should have filed a claim. Second, it is evident that submission of
claims to these individuals was sufficient to receive at least a portion of payment on the claims.
See Def.’s App. A94 (approval dated Dec. 10, 2009), A152 (approval dated July 13, 2010), A221
(approval dated Oct. 4, 2010), A235 (approval dated Dec. 20, 2010). Third, these individuals
responded to Rollock’s submission of claims with either payment or an explanation refusing
payment – including a letter from Ms. Beyer constituting “a final response.” Def.’s App. A248;
see also Def.’s App. A94 (Beyer’s recommendation for payment), A159 (Beyer’s request for
additional documentation to enable processing of a claim), A165 (Beyer’s statement of NPS’s
position on monitoring costs), A211 (Conte’s reiteration of NPS’s position on monitoring,

                                                12
containing citations to portions of the Agreement). 21 If, as the government contends, they were
unauthorized to respond, this was not evident in any of the correspondence. Moreover, as stated
in United Partition Sys., Inc. v. United States, 59 Fed. Cl. 627 (2004), “[t]his [c]ourt has rejected
attempts by the government to attack a contractor’s submission of a claim based on its delivery
to the wrong government employee.” Id. at 638 (citing Flying Horse v. United States, 49 Fed.
Cl. 419, 428-29 (2001) (plaintiff did not know who the proper contracting officer was and
government failed to make proper inquiry and forward the claim)). Correlatively, the Federal
Circuit has held that in the obverse situation, i.e., transmission from the government to the
contractor, the submission need only be delivered to an authorized agent of the contractor to
fulfill the requirements of the CDA. See Borough of Alpine v. United States, 923 F.2d 170, 172
(Fed. Cir. 1991).

       The government also argues that the claims were not properly certified as required by
Section 7103(b) of the CDA. Def.’s Reply at 7. 22 In asserting this position, however, the

       21
          In the proceedings before NPS, the parties referred to monitoring costs generally,
without distinguishing between those related to disposition of the scrap inventory and those
related to excavation of the embedded material. As discussed supra, at 10-11, only Rollock’s
claims regarding monitoring of the scrap inventory are subject to the CDA.
       22
            In relevant part, the statute provides that:

                  For claims of more than $100,000 made by a contractor, the contractor
                   shall certify that —
                  (A) the claim is made in good faith;
                  (B) the supporting data are accurate and complete to the best of the
                  contractor’s knowledge and belief;
                  (C) the amount requested accurately reflects the contract adjustment
                  for which the contactor believes the Federal Government is liable; and
                  (D) the certifier is authorized to certify the claim on behalf of the contractor.

41 U.S.C. § 7103(b)(1).

           The certification on the form provided by NPS for use with the Relocation Act, which
was actually used by Rollock, states that:

                  I (we) CERTIFY under the penalties and provisions of U.S.C. Title
                  18, Sections 286, 287, 1001, and any other applicable law, that this
                  claim and information submitted herewith have been examined by
                  me (us) and are true, correct, and complete. I (we) further certify
                  that I (we) have not submitted any other claim for, or received
                  reimbursement or compensation from any other source for any
                  item of this claim, and that any receipts submitted herewith
                  accurately reflect costs actually incurred. I (we) further certify that
                  my (our) choice of payment was made on the basis of a full

                                                     13
government fails to account for the fact that Rollock did not file a single claim for monitoring
costs but rather submitted a series of claims, none amounting to over $100,000. See Def.’s App.
A87 (claim for $15,840), A104 (claim for $26,565), A110 (claim for $18,180), A119 (claim for
$16,060), A127 (claim for $12,060), A231 (claim for $76,305). Therefore, no certification was
necessary. Regardless, the court is satisfied that Rollock’s certification on NPS’s form for a
“Claim for Relocation Payment” satisfies the certification requirements of Paragraph 7103(b)(1)
of the CDA. Rollock’s claim for monitoring costs, as it relates to costs associated with the sale
of business scrap, is within the court’s jurisdiction under the CDA. 23

                              D. Suit Under the Relocation Act

        The government argues that the court cannot exercise subject matter jurisdiction over any
claims under the Relocation Act because Rollock has failed to exhaust its administrative
remedies. Def.’s Mot. at 13. The doctrine of exhaustion of administrative remedies provides
that “no one is entitled to judicial relief for a supposed or threatened injury until the prescribed
administrative remedy has been exhausted.” Myers v. Bethlehem Shipbuilding Corp., 303 U.S.
41, 50-51 (1938). Although the government frames its exhaustion argument as a threshold
jurisdictional question, the doctrine of exhaustion includes both statutory exhaustion, which is
jurisdictional, and prudential exhaustion, which is not. See McCarthy v. Madigan, 503 U.S. 140,
144 (1992), superseded by statute on other grounds, Prison Litigation Reform Act of 1995, Pub.
L. No. 104-134, 110 Stat. 1321-71 (1996) (codified as amended at 42 U.S.C. § 1997e, et seq.), as
recognized in Woodford v. Ngo, 548 U.S. 81, 84-85 (2006); see also White & Case LLP v.
United States, 67 Fed. Cl. 164, 169 (2005).

         Statutory exhaustion is required “[w]here Congress specifically mandates” it, McCarthy,
503 U.S. at 144, with “sweeping and direct statutory language indicating that there is no federal
jurisdiction prior to exhaustion, or the exhaustion requirement is treated as an element of the
underlying claim.” Elk v. United States, 70 Fed. Cl. 405, 407 (2006) (internal quotation marks
omitted) (quoting Avocados Plus Inc. v. Veneman, 370 F.3d 1243, 1248 (D.C. Cir. 2004)).
Contrastingly, prudential exhaustion places the decision of whether to require exhaustion prior to
judicial review within the sound discretion of the court. McCarthy, 503 U.S. at 144. In
exercising judicial discretion, the court considers “the ‘twin purposes of protecting
administrative agency authority and promoting judicial efficiency.’” White & Case, 67 Fed. Cl.
at 170 (quoting McCarthy, 503 U.S. at 145). The court considers these two exhaustion principles
in turn.

               explanation by the displacing agency representative of the
               differences between the types of payments available.

Def.’s App. A94, A152, A221, A235.
       23
          Even assuming that the certifications were inadequate, any defect in the certifications
“does not deprive a court . . . of jurisdiction over the claim.” 41 U.S.C. § 7103(b)(3). Rather,
the court simply must “require a defective certification to be corrected.” Id.

                                                14
       1.   Statutory exhaustion.

        In the government’s view, the Relocation Act and its regulations provide sufficient
evidence to indicate that statutory exhaustion applies. See Def.’s Mot. at 13-18. In support of its
argument, the government cites to legislative history indicating that Congress sought in the
Relocation Act to provide an administrative process as “‘an alternat[ive] to judicial review.’”
Def.’s Mot. at 14-15 (quoting H.R. Rep. No. 91-1656 (1970), reprinted in 1970 U.S.C.C.A.N.
5850, 5855). Correlatively, the Department of Transportation’s regulations establishing a
process for submission of claims coupled with administrative appeals procedures express an
objective to “minimize litigation and relieve congestion in the courts.” 49 C.F.R. § 24.1(a); see
also 42 U.S.C. § 4651.

         The Relocation Act is silent insofar as judicial action is concerned. No jurisdictional
grant or waiver of sovereign immunity is provided. Claimants are thus forced to turn to other
statutes as a basis for juridical redress. District courts can take jurisdiction over Relocation Act
claims pursuant to the federal question statute, 28 U.S.C. § 1331, but that statute does not supply
a waiver of sovereign immunity for suits against the federal government, see, e.g., Reed v. Reno,
146 F.3d 392, 397-98 (6th Cir. 1998) (citing Sibley v. Ball, 924 F.2d 25, 28 (1st Cir. 1991), aff’d
upon transfer, 944 F.2d 913 (Fed. Cir. 1991)). The Administrative Procedure Act (“APA”), 5
U.S.C. § 702, however, specifically waives sovereign immunity where it applies, see Black Hills
Inst. of Geological Research v. South Dakota School of Mines & Tech., 12 F.3d 737, 740 (8th
Cir. 1993) (“Section 702 waives the federal government’s sovereign immunity in cases
challenging agency action . . . and seeking relief other than money damages.”), and that waiver
can be coupled with jurisdiction under the federal question statute, see Califano v. Sanders, 430
U.S. 99, 105-07 (1977) (addressing the effect of the amendment of Section 1331 in 1976, to
remove an amount-in-controversy requirement); cf. A.E. Finley & Associates, Inc. v. United
States, 898 F.2d 1165 (6th Cir. 1990) (holding that APA waives sovereign immunity in a suit
brought under the federal question jurisdictional statute). The waiver pertains to “[a]gency
action made reviewable by statute and final agency action for which there is no other adequate
remedy in a court.” 5 U.S.C. § 704. The “adequate remedy” limitation on APA review
ordinarily bars a suit against the federal government for money damages in a district court where
such damages are available in a suit in this court. See, e.g., Brazos Elec. Power Co-op v. United
States, 144 F.3d 784, 786-88 (Fed. Cir. 1998) (affirming an order by a district court transferring
a case to the Court of Federal Claims where damages were sought for breach of contract);
Alabama Rural Fire Ins. Co. v. Naylor, 530 F.2d 1221, 1228-30 (5th Cir. 1976) (holding that a
suit seeking damages for breach of contract belonged in the Court of Claims and not the district
court under the APA); cf. Transohio Sav. Bank v. Director, Office of Thrift Supervision, 967 F.2d
598, 607-08 (D.C. Cir. 1992) (ruling that district court had jurisdiction over a suit for equitable
relief under the waiver of sovereign immunity in the APA, because the Claims Court could not
grant the requested equitable relief). 24

       24
          In Boyd v. Browner, 107 F.3d 922 (D.C. Cir. 1996) (Table, decision available at 1996
WL 678614), the D.C. Circuit instructively considered the jurisdiction available to a district
court under the federal question statute and the APA, as contrasted to that provided to a district
court and the Court of Federal Claims under the Little Tucker Act and Tucker Act, respectively.
See id., 1996 WL 678614, at *2-*4.

                                                15
        The Little Tucker Act, 28 U.S.C. § 1346(a)(2), provides district courts with a waiver of
sovereign immunity for claims against the federal government but only for claims seeking
money damages up to $10,000. Suits in district court respecting claims under the Relocation Act
are consequently not often filed under the Little Tucker Act. And, where district courts have
taken jurisdiction over Relocation Act claims pursuant to Section 1331 and reliant upon the
APA’s waiver of sovereign immunity, they have found an exhaustion requirement because the
APA independently requires exhaustion of all available administrative remedies, i.e., the agency
action must be “final” before a suit may be brought, regardless of whether the underlying statute
requires exhaustion. See, e.g., Dalton v. Las Vegas, 282 Fed. Appx. 652, 656 (10th Cir. 2008);
Consumers Power Co. v. Costle, 468 F. Supp. 375, 380 (E.D. Mich. 1979), aff’d, 615 F.2d 1147
(6th Cir. 1980); 249.12 Acres of Land v. United States, 414 F.Supp. 933, 935 (W.D. Okla. 1976);
Smith v. Cookeville, 381 F. Supp. 100, 102, 106 (M.D. Tenn. 1974).

        In this court, jurisdiction regarding Relocation Act claims depends upon the grant
provided by the Tucker Act. In this context, the government relies on Mayne v. United States, 13
Cl. Ct. 60 (1987), to support its argument that a claim for damages under the Relocation Act
requires statutory exhaustion. Def.’s Mot. at 16. That reliance is inappropriate. The court in
Mayne required exhaustion on prudential, not statutory, grounds. Mayne, 13 Cl. Ct. at 65. In
addition, Mayne is distinguishable from the case at hand in two ways. First, in Mayne, the
plaintiffs never filed any claim with the government agency prior to bringing the case before the
court. Id. The court’s determination that plaintiffs failed to exhaust their administrative
remedies reflected this failure to initiate the agency process or even to inform the agency of the
dispute. Id. Rollock, on the other hand, submitted administrative claims to NPS prior to filing
suit. Second, the plaintiffs in Mayne had no contract with the agency respecting relocation
assistance. Contrastingly, Rollock has a specific relocation agreement over which it is suing.

        Unlike the APA, the Tucker Act does not require exhaustion of permissive administrative
remedies before bringing a suit in this court, but it does require exhaustion of mandatory
administrative remedies. See Martinez v. United States, 333 F.3d 1295, 1304 (Fed. Cir. 2003).
Whether an administrative remedy is permissive or mandatory rests on whether Congress
specifically intended for the agency to retain a right to complete initial decision-making
authority. Id. at 1305. The court’s military pay cases illustrate this distinction. Claims for
unlawful discharge brought under the Military Pay Act, 37 U.S.C. § 204, can be submitted either
to a military corrections board or to a court because the cause of action has been held to accrue at
the time of discharge, separation, or other definitive action, and the service member may sue
immediately. See Chambers v. United States, 417 F.3d 1218, 1224 (Fed. Cir. 2005); Martinez,
333 F.3d at 1303. Thus, the option to go before the military corrections board is considered “a
permissive administrative remedy and . . . not a mandatory prerequisite to filing a Tucker Act
suit challenging the discharge.” Martinez, 333 F. 3d at 1304 (citing Richey v. United States, 322
F.3d 1317, 1325 (Fed. Cir. 2003). In determining that wrongful military discharge claims accrue
immediately upon discharge, separation, or other definitive action, the Federal Circuit looked to
Congress’s intent when creating the military correction boards. Prior to creation of the
correction boards, service members could bring claims before the Court of Claims or seek a
private bill of redress from Congress. See id. at 1306-07. A service member was not first
required to seek redress from Congress before bringing a claim in the Court of Claims. See id.
When Congress created the military corrections boards to relieve its burden to address individual

                                                16
requests for private bills, it did not evidence that it was attempting to create a new rule of
exhaustion. See id. at 1307-08; see also Ogden v. Zuckert, 298 F.2d 312, 314-15 (D.C. Cir.
1971) (“The Board furnishes a means by which to seek correction of error or injustice, but
neither statute nor regulation requires this means to be pursued as a condition to finality of the
Secretary’s action.”).

         On the other hand, claims of entitlement to disability retirement pay, arising under 10
U.S.C. § 1201, are subject to an administrative exhaustion requirement because such claims “do
not accrue until the appropriate military board either finally denies such a claim or refuses to
hear it.” Chambers, 417 F.3d at 1224. As a result, exhaustion of the available administrative
procedure is mandatory prior to bring a Tucker Act claim to court. Id. at 1225 (citing Friedman
v. United States, 310 F.2d 381, 392 (Ct. Cl. 1962)). Unlike military discharge cases, in disability
retirement cases, “Congress has entrusted the military boards with the task of determining
whether a serviceman should be retired for disability and therefore . . . no cause of action arises
. . . until a proper board has acted or declined to act.” Friedman, 310 F.2d at 389. Courts have
consistently held that a determination by the secretary of the pertinent military branch that a
service member is or is not entitled to disability retirement pay is a pre-requisite to judicial
action. See, e.g., Levadi v. United States, 146 F. Supp. 455, 456 (Ct. Cl. 1956). In Levadi, the
court explained that without a determination by the Secretary, no right to disability retirement
pay has been granted or denied. No such Congressional constraint exists in claims of unlawful
discharge or separation. See Martinez, 333 F.3d at 1304.

         The Relocation Act and its regulations provide no indication that Congress sought to
require agency appeals prior to judicial review. The Relocation Act’s authorization to
promulgate appeal procedures is written in permissive terms. The statute states that the “head of
the lead agency is authorized to issue such regulations and establish such procedures as he may
determine to be necessary.” 42 U.S.C. § 4633(b) (emphasis added). Congress did not even
mandate the existence of an agency appeals process under the Relocation Act. The inquiry does
not end there. Because Congress delegated the task of establishing procedures for administrative
claims to the lead agency, the Department of Transportation, see U.S.C. § 4633(b), quoted supra,
at 9, the court must consider the regulations promulgated by that department. Cf. Sandvik Steel
Co. v. United States, 164 F.3d 596, 599-600 (Fed. Cir. 1998) (considering the agency’s
regulations when “Congress did not prescribe the scope of determination proceedings”); Elk, 70
Fed. Cl. at 407-08 (looking at regulations to determine executive branch intent when resolving
the existence of statutory exhaustion). Here, the relevant regulation, found at 49 C.F.R. § 24.10,
does not provide a comprehensive scheme for appeals. In fact, Rollock was not informed that
this regulation formed the basis of the appeals process. In addition, Subsection 24.10(b) states
that “[a]ny aggrieved person may file a written appeal.” 49 C.F.R. § 24.10(b) (emphasis added);
see Massie v. United States Dep’t of Housing & Urban Dev., 620 F.3d 340, 359 (3d Cir. 2010)
(holding that regulations of the Department of Housing and Urban Development under the
Relocation Act, consisting of the same language as Part 24, do not require exhaustion of
administrative remedies). As the Third Circuit instructively observed in Massie,

               [t]he relevant regulation related to the Relocation Act merely
               allows for an administrative appeal, which a party “may file,” but
               does not require this, 24 C.F.R. § 290.17(f). In Darby v. Cisneros,

                                                 17
               509 U.S. 137, 154 (1993) [parallel citations omitted], the Supreme
               Court held that “where the APA applies, an appeal to ‘superior
               agency authority’ is a prerequisite to judicial review only when
               expressly required by statute or when an agency rule requires
               appeal before review and the administrative action is made
               inoperative pending that review.” Here such review is not
               expressly required, but merely permitted, and hence exhaustion of
               the administrative appeal process was not necessary.

620 F.3d at 359 (emphasis in the original). In short, the regulations addressing administrative
appeals cannot be characterized as “sweeping and direct” in requiring exhaustion. See Elk, 70
Fed. Cl. at 407. Without an expression of explicit intent from Congress and given the permissive
nature of the pertinent regulations promulgated by the Department of Transportation as the lead
agency pursuant to Congress’s delegation, the court cannot find that statutory exhaustion of
administrative remedies is necessary before filing a Relocation Act claim in this court. 25

       2. Prudential exhaustion.

       Having found that the Relocation Act itself does not require exhaustion of administrative
appeals before filing a claim in this court, the pertinent question becomes whether, for prudential
reasons, the court should require exhaustion of administrative appeals.

         In considering prudential exhaustion, the court is called to balance the interests of the
individual, which favor prompt access to a judicial forum, see McCarthy, 503 U.S. at 146
(“[F]ederal courts are vested with a ‘virtually unflagging obligation’ to exercise the jurisdiction
given them.” (quoting Colorado River Water Conservation Dist. v. United States, 424 U.S. 800,
817-18 (1976))), against countervailing institutional interests, see Elk, 70 Fed. Cl. at 408 (citing
McCarthy, 503 U.S. at 146). The Federal Circuit has “long held that, in Tucker Act suits, a
plaintiff is not required to exhaust a permissive administrative remedy before bringing suit.”
Martinez, 333 F.3d at 1304. A court should also consider “at least three broad sets of
circumstances” that weigh against imposing prudential exhaustion. McCarthy, 503 U.S. at 146.
First, the court should not require exhaustion if the administrative remedy may create undue
prejudice to subsequent court action, specifically in cases where there is an unreasonable or
indefinite timeframe at the agency level. Id. at 146-47. Conversely, the administrative remedy
may be helpful to provide the agency with an opportunity to develop an administrative record,
correct errors, and narrow the issues needing judicial resolution. See Itochu Bldg. Prods. v.
United States, 733 F.3d 1140, 1145 (Fed. Cir. 2013). Second, requiring exhaustion is not
advisable when there is “doubt as to whether the agency [is] empowered to grant effective
relief.” McCarthy, 503 U.S. at 147 (internal quotation marks and citation omitted). Third,

       25
          The Department of Transportation’s regulation does not purport to condition judicial
action on completion of the administrative process. Indeed, the only mention of a judicial role in
the regulation is in Subsection 24.10(g), which states that a person who received less than full
relief requested from the agency process “shall [be] advised . . . of his or her right to seek judicial
review of the [a]gency decision.” 49 C.F.R. § 24.10(g).

                                                  18
exhaustion should not be required when the administrative body “is shown to be biased or has
otherwise predetermined the issue before it.” Id. at 148 (internal citation omitted).

        Although the regulations in Part 24 provide some assurances regarding agency review,
e.g., Subsection 24.10(g) requires prompt review by the agency and Subsection 24.10(h) requires
a disinterested reviewer, 49 C.F.R. §§ 24.10(g), (h), the Department of the Interior’s
implementation of these regulations is uncertain and indefinite in its contours. First, Rollock was
not informed of any statutory or regulatory authority regarding the appeals process. As a result,
it was not told of the extent of its rights or the details of the review process. Second, the
information NPS did provide to Rollock is at odds with the timeline requirements in the
Department of Transportation’s overarching and binding regulations. Subsection 24.10(c) states
that an agency “may set a reasonable time limit” for filing an appeal but that “[t]he time limit
shall not be less than 60 days after the person received written notification of the [a]gency’s
determination on the person’s claim.” 49 C.F.R. § 24.10(c). In short, Interior may set a
reasonable time limit within which a person may file an appeal, but that time limit has to be at
least 60 days or more. NPS’s notifications, however, all stated that an appeal must be filed
within 60 days. See Def.’s App. A245, A295, A322, A340, A346. 26 Finally, Interior’s
regulations do not provide information regarding how hearings will be conducted, what material
should be submitted, or how evidence will be weighed. The Department of the Interior’s process
for handling hearings and appeals is geared to issues regarding Indian affairs, public lands,
federal oil and gas royalties, and surface coal mining regulations, see 43 C.F.R. Part 4, Subparts
D, E, J, and L, although Interior did include a general catch-all subpart that covers unspecified
hearings and appeals, see 43 C.F.R. Part 4, Subpart G, and that catch-all would apply in this
instance.

        In this instance, because NPS addressed some of Rollock’s claims but not others, it is not
apparent how Interior’s rules regarding appeals would be applied, especially to the claims NPS
did not decide, even tentatively. Ordinarily, the agency would have an institutional concern that
it have an opportunity to develop the factual record of a disputed matter. If this case were to be
dismissed on grounds of prudential exhaustion, the court’s concerns regarding the process would
remain unresolved. See Elk, 70 Fed. Cl. at 409 n.3. Given the court’s general determination that
the exhaustion of a permissive administrative process is not necessary in Tucker Act suits, along
with the concerns regarding Interior’s process for reviewing NPS decisions, the court declines to
require prudential exhaustion of the administrative appeal remedy.

       3. Jurisdictional questions apart from exhaustion.

       In addition to the considerations of exhaustion, the court has an obligation to determine if
additional hindrances to jurisdiction exist. Generally this court has exclusive jurisdiction over
claims arising under contracts with the federal government in which the plaintiff seeks more than
$10,000 in damages. See 28 U.S.C. § 1346(a)(2); see also Greenhill v. Spellings, 482 F.3d 569,

       26
           More confusingly, regulations promulgated by the Department of the Interior that
govern its generally applicable appeals process require a person to “file a written notice of appeal
. . . within 30 days” from the date of the decision. 43 C.F.R. § 4.701 (emphasis added).

                                                19
573 (D.C. Cir. 2007). This is such a case, and no impediments appear to arise with this court’s
exercise of jurisdiction to consider Rollock’s claims under the Tucker Act. 27

                                             E. Remand

        Once the court determines that a case is within its jurisdiction, it has juridical power to
enter an order remanding the case to another body, either at the request of a party or on its own
motion. See Emerald Coast Finest Produce Co. v. United States, 75 Fed. Cl. 549, 553 (2007)
(citing 28 U.S.C. § 1491(a)(2)). The Tucker Act grants this court “the power to remand
appropriate matters to any administrative or executive body or official with such direction as it
may deem proper and just.” 28 U.S.C. § 1491(a)(2). When the factual record before the court is
incomplete or additional agency proceedings or action are necessary, a remand may be

       27
           The Relocation Act does not displace the jurisdiction that would arise under the Tucker
Act. The Supreme Court recently addressed the criteria for such displacement in United States v.
Bormes, __ U.S. __, 133 S. Ct. 12 (2012), where the Court determined that the Little Tucker Act
was displaced, and therefore this court and the Federal Circuit lacked jurisdiction, when a
separate statute contained a detailed “self-executing remedial scheme.” Bormes, __ U.S. at __,
__, 133 S. Ct. at 18. Although the Court in Bormes was primarily analyzing the grant of
sovereign immunity in the Little Tucker Act, 28 U.S.C. § 1346(a)(2), rather than the Tucker Act,
28 U.S.C. § 1491(a)(1), “[a]s relevant here, the scope of the two statutes is otherwise the same.”
Bormes, __ U.S. at __, 133 S. Ct. at 16 n.2. When faced with a statute containing a detailed
remedial scheme, the Court considered that a lower court should examine the statute’s “own
text” to determine the extent of damages liability and whether a waiver of sovereign immunity
exists before proceeding on the merits. Id. at 19. If a statute provides a detailed and
comprehensive enforcement regime standing apart from the Tucker Act, a plaintiff cannot “mix
and match” the Tucker Act’s grant of sovereign immunity with the damages or jurisdictional
provisions of such a statute. Id. In this instance, unlike the statute in Bormes, which specified a
statute of limitations and permissible venues for claims brought under the Federal Credit
Reporting Act, neither the Relocation Act nor the Department of Transportation’s regulations
provide a detailed remedial scheme. The regulations only refer generally to “judicial review.”
49 C.F.R. § 24.10(g). Thus, the Bormes displacement doctrine does not apply here, and it is
appropriate to combine the Tucker Act’s waiver of sovereign immunity with the Relocation
Act’s right to money damages. See United States v. White Mountain Apache Tribe, 537 U.S.
465, 472-73 (2003).
           Separately, where money claims seeking specific relief rather than money damages are
at issue, jurisdiction may also be excluded from this court’s purview under the precedent
established in Bowen v. Massachusetts, 487 U.S. 879, 905 (1988). Because this court lacks
general equitable powers, the district courts are the appropriate forum for equitable monetary
relief. Id. In Bowen, Massachusetts was awarded prospective injunctive relief for the
government’s refusal to reimburse the state for Medicaid expenses, which in essence provided
monetary relief by way of an adjustment to future payments but did not provide a judgment for
money. Id. at 909. Rollock’s claims are properly considered claims for money damages because
they seek a monetary judgment for alleged breach of contract. See Greenhill v. United States, 81
Fed. Cl. 786, 790 (2008) (“[M]oney damages are the default remedy for breach of contract.”)

                                                20
appropriate. See Todd Constr., L.P. v. United States, 88 Fed. Cl. 235, 245 (2009); Emerald
Coast, 75 Fed. Cl. at 553. Both deficiencies exist here. NPS did not act on a number of
Rollock’s claims, and, when it did act, it left salient matters unresolved. NPS should further
develop the factual record and definitively act on Rollock’s claims.

                                      CONCLUSION

        For the reasons stated above, the government’s motion to dismiss is DENIED, as is its
alternative motion for summary judgment. The portion of the claim for monitoring costs of the
sale of metal scrap is governed by the CDA and Rollock has satisfied the claim requirements
under that statute. The portion of the claim for monitoring costs of the embedded materials and
the claim for relocation costs of the embedded materials are governed by the Relocation Act.
The court has jurisdiction over these claims because the Relocation Act does not require
exhaustion of administrative remedies.

       Pursuant to RCFC 52.2, this case is remanded to the National Park Service for a period of
six months. See RCFC 52.2(b)(1)(B). The case is stayed pending the results of the remand. See
RCFC 52.2(b)(1)(C). The court requests that the parties file a status report on or before 90 days
from the date of this decision, regarding the progress of the remand. See RCFC 52.2(b)(1)(D).

       It is so ORDERED.

                                                  s/ Charles F. Lettow
                                                  Charles F. Lettow
                                                  Judge

                                                21