Court Opinion

ID: 3112512
Source: CourtListenerOpinion
Date Created: 2015-10-16 07:04:42.987435+00
Date Added: 2024-06-11T11:52:34.687470
License: Public Domain

NO. 07-08-0312-CV

                            IN THE COURT OF APPEALS

                     FOR THE SEVENTH DISTRICT OF TEXAS

                                    AT AMARILLO

                                      PANEL C

                                 DECEMBER 6, 2010

                        ______________________________

                        ANOTHER ATTIC, LTD., APPELLANT

                                          V.

   PLAINS BUILDERS, INC., WENDY WHITE, AS INDEPENDENT EXECUTRIX OF
     THE ESTATE OF G. TIM WHITE, FORMERLY D/B/A WHITE ASSOCIATES
      ARCHITECTURE, AND CHAVEZ CONCRETE COMPANY, APPELLEES

                      _________________________________

              FROM THE 64TH DISTRICT COURT OF HALE COUNTY;

            NO. A33892-0502, HONORABLE ROBERT KINKAID, JUDGE

                       _______________________________

Before QUINN, C.J., and HANCOCK and PIRTLE, JJ.

                             MEMORANDUM OPINION

      Appellant, Another Attic, Ltd. ("Another Attic"), a limited liability partnership,

appeals from a judgment rendered in favor of Appellees, Plains Builders, Inc. ("Plains

Builders"), Wendy White, as Independent Executrix of the Estate of G. Tim White,

formerly d/b/a White Associates Architecture ("White"), and Chavez Concrete Company

("Chavez"), in a contract dispute lawsuit arising out of a written contract. By eight
issues, Another Attic questions the liability determination (Issues 1 through 4), the legal

sufficiency of the damages (Issue 5), the trial court's finding that the contract was

unambiguous (Issue 6), its failure to submit certain instructions and questions (Issue 7),

and its award of attorney's fees (Issue 8).             We modify the judgment and affirm as

modified.

                                       Factual Background

        In 2004, Plains Builders and Another Attic executed a written contract for the

construction of a mini-storage facility in Plainview, Texas.                         Plains Builders

subcontracted the architect-related work to White and concrete work to Chavez.

Construction began in May of that year; however, towards the end of construction,

disputes arose about the work being performed by Plains Builders. By a letter dated

October 8, 2004, Another Attic directed Plains Builders to cease work, which it did.

Plains Builders contended that, at the time it was ordered off the project, Another Attic

owed it $57,938 under the terms of the contract. According to Plains Builders this sum

was calculated by deducting from the full contract price, the sum of the amounts already

paid plus the value of work that was not performed by Plains Builders due to Another

Attic's termination of the contract.1         Another Attic refused to pay this sum and on

February 4, 2005, Plains Builders filed suit for breach of contract for failure to pay,

declaratory judgment as to substantial completion, and enforcement of its statutory

mechanic's and materialmen's lien. Asserting lack of substantial completion, Another

1
 Plains Builders contends that it allowed credit to Another Attic for items of work that had not yet been
completed at the time it was ordered off the job. Specifically, Plains Builders offered evidence that it
allowed credit for its "cost plus all markup" relating to installation of the gate operating system,
landscaping, and sprinklers.
                                                   2
Attic filed multiple counterclaims against Plains Builders, as well as a third-party claim

against two of the subcontractors, the architect, White, and the concrete provider,

Chavez. Another Attic contended the work performed was so defective the alleged

deficiencies could not be remedied without having the entire facility torn down and

rebuilt.   Another Attic also contended that certain provisions of the contract were

ambiguous.

       On April 5, 2008, the trial court submitted the dispute to a jury based upon

thirteen questions. The first two questions dealt with the issue of contract liability, as it

pertained to the dispute between Another Attic and Plains Builders. As submitted to the

jury, questions one and two, together with the jury's verdict, provided as follows:

       QUESTION NO. 1

       Did ANOTHER ATTIC fail to comply with the construction contract?

               You are instructed that a "failure to comply" is an unjustified failure
       or refusal of one of the parties to the contract to perform all or part of what
       is promised in the contract. Failure to comply by Another Attic would be
       excused by a previous failure by Plains Builders to comply with a material
       obligation of the same agreement. A failure to comply must be material.
       A "failure to comply" becomes material when it deprives the injured party
       of any substantial benefit which the injured party could reasonably have
       anticipated. The less the non-breaching party is deprived of expected
       benefit, the less material the breach.

       Answer "Yes" or "No"

       Answer: Yes

       QUESTION NO. 2

       Did PLAINS BUILDERS fail to comply with the construction contract?

              You are instructed that a "failure to comply" is an unjustified failure
       or refusal of one of the parties to the contract to perform all or part of what
       is promised in the contract. Failure to comply by Plains Builders would be
                                              3
       excused by a previous failure by Another Attic to comply with a material
       obligation of the same agreement. A "failure to comply" must be material.
       A "failure to comply" becomes material when it deprives the injured party
       of any substantial benefit which the injured party could have [sic]
       reasonably have anticipated. The less the non-breaching party is
       deprived of expected benefits, the less material the breach.

       Answer "Yes" or "No"

       Answer: No_

       Another Attic did not object to the submission of these liability questions or the

corresponding instructions in any respect material to this appeal. By these issues the

jury was asked to determine whether Another Attic and/or Plains Builders materially

breached the contract. Simply stated, the jury decided that Another Attic did (excusing

Plains Builders from further performance) and that Plains Builders did not (thereby

rejecting Another Attic's defective construction claims).

       Having found that Another Attic had breached the contract in question (Question

No. 1), and that Plains Builders had not (Question No. 2), the jury concluded that as a

result thereof, Plains Builders had been damaged in the sum of $57,938 (Question No.

3).   The jury also found that neither White, nor Chavez, had negligently damaged

Another Attic (Question Nos. 10 and 12, respectively).         Due to their conditional

submission, the remaining jury questions were unanswered. Following cross-motions

for judgment, on July 15, 2008, the trial court entered judgment that Plains Builders

recover of and from Another Attic the sum of $57,938, plus attorney's fees, pre-

judgment interest and costs of court, together with foreclosure of its mechanic's and

                                             4
materialmen's lien. The judgment further provided that Another Attic take nothing as to

White and Chavez and that it recover costs of court from Another Attic.

                Substantial Performance Versus Excused Performance

       A considerable portion of Another Attic's arguments is predicated on the premise

that Plains Builders's theory of recovery was based upon the equitable doctrine of

substantial performance. At trial and on appeal, Another Attic has pursued a theory that

defects in the construction of the mini-storage facility were so material they could not be

remedied without the entire facility being torn down and rebuilt. Another Attic posits that

because substantial performance requires that any defects be remediable without doing

material damage to the structure, there can be no substantial performance as a matter

of law.   Plains Builders counters this argument by contending that "this is not a

substantial performance case," or, alternatively, that the defects that could not be

remediated without doing material damage to the structure, if any, were immaterial.

Plains Builders further contends that this is a suit for "breach of contract, quantum

meruit and unjust enrichment."2

       In an ordinary contract case, a party who has materially breached a contract

cannot maintain a suit on the contract for its breach by the other party to the contract.

Gulf Pipe Line Co. v. Nearen, 135 Tex. 50, 56, 138 S.W.2d 1065, 1068 (Tex. 1940).

However, in the area of construction contracts, this strict rule has been relaxed by the

equitable doctrine of substantial performance which allows a breaching party who has

"substantially completed" a construction contract to sue for the recovery of damages

2
Plains Builders's quantum meruit and unjust enrichment claims were not submitted to the jury.
                                                  5
under that contract rather than being relegated to a cause of action based on breach of

contract and quantum meruit. See Dobbins v. Redden, 785 S.W.2d 377, 378 (Tex.

1990); Vance v. My Apartment Steak House of San Antonio, Inc., 677 S.W.2d 480, 481

(Tex. 1984); RAJ Partners, Ltd. v. Darco Constr. Corp., 217 S.W.3d 638, 643 (Tex.App.

--Amarillo 2006, no pet.). By definition, the doctrine recognizes that the contractor has

breached his obligations under the contract; and, accordingly, his recovery is decreased

by the cost of remedying those defects or omissions for which he is responsible.

Vance, 677 S.W.2d at 482. The doctrine also assumes that, if there is substantial

performance by the contractor, any breach by the contractor is immaterial. R.B. Hardy

& Sons, Inc. v. Hoyer Global (USA), Inc., No. 01-09-0041-CV, 2010 Tex.App. LEXIS

4373, at *18-19, (Tex.App.--Houston [1st Dist.] June 10, 2010, pet. filed).

       Substantial performance is not, however, the exclusive theory upon which a

contractor can pursue recovery in a dispute concerning a construction contract where

that contractor has not completed full performance of the contract. Under the doctrine

of repudiation, a party's further performance under a contract is excused if the opposing

party has repudiated the contract. Burford v. Pounders, 145 Tex. 460, 465-67, 199
S.W.2d 141, 144-45 (Tex. 1947).        A repudiation occurs when a party absolutely

repudiates the obligation, without just excuse, and the other party is damaged by the

repudiation.   Consumer Portfolio Servs. v. Obregon, No. 13-09-00548-CV, 2010

Tex.App. Lexis 8835, at *11-12, (Tex.App.--Corpus Christi Nov. 4, 2010, no pet. h.)

(mem. op.). Furthermore, in those situations where the other party to the contract has

materially breached the contract, the contractor's failure to complete full performance

                                            6
may be excused. Mustang Pipeline Co. v. Driver Pipeline Co., 134 S.W.3d 195, 198

(Tex. 2004); Lazy M Ranch v. TXI Operation, LP, 978 S.W.2d 678, 680-81 (Tex.App.--

Austin 1998, pet. denied).

      In cases where a contractor has not fully performed his obligations under the

contract, neither the doctrine of substantial performance nor the doctrine of excused

performance permits the breaching contractor to recover the full consideration provided

for in the contract. Where the theory of recovery has been substantial performance,

courts have limited the amount recoverable by the contractor to "the contract price, less

the reasonable cost of remedying the defects or omissions in such a way as to make

the building conform to the contract." Atkinson v. Jackson Bros., 270 S.W. 848, 851

(Tex. Comm'n App. 1925, holding approved). Where a contractor has failed to complete

a construction contract because full performance has been excused due to a material

breach or repudiation of the contract by the owner, courts have limited the amount

recoverable by the contractor to the damages suffered by reason of the breach of

contract. Dankowski v. Cremona, 352 S.W.2d 334, 336 (Tex.App.--Eastland 1961, writ

ref'd n.r.e.) Equity requires that the contractor recover that amount of money which

would place the contractor in a position equivalent to that which he would have

occupied if there had been no breach, and the contract had been fully performed. Id. In

such situations, the contractor is entitled to recover the value of his work had the

contract been completed, i.e., the contract price, less the value of any work not

completed due to the builder's repudiation or material breach.       Dill v. Helms, 468
S.W.2d 608, 611 (Tex.App.--Waco 1971, writ ref'd n.r.e.).

                                           7
                                         Issue One

       By its first issue, Another Attic contends the trial court erred by denying its motion

for instructed verdict and motion for judgment non obstante veredicto because there

was no substantial completion as a matter of law.

       The denial of a motion for instructed verdict may be reviewed on appeal only if

that ruling has been recited in a formal order or in the final judgment. See Wal-Mart

Stores, Inc. v. Berry, 833 S.W.2d 587, 590 (Tex.App.--Texarkana 1992, writ denied).

The oral denial of a directed verdict is insufficient to preserve error. Id. Because the

denial of Another Attic's motion for directed verdict is not contained in a written order of

the trial court, nothing is preserved for review.

       A trial court may disregard a jury finding and enter a judgment non obstante

veredicto ("JNOV") if a directed verdict would have been proper, or if there is no

evidence to support one or more of the jury findings necessary to liability. See Tex. R.

Civ. P. 301; Tiller v. McLure, 121 S.W.3d 709, 713 (Tex. 2003). We review the denial of

a motion for JNOV under a "no evidence" standard, meaning we credit evidence

favoring the jury verdict if a reasonable juror could, and disregard contrary evidence

unless reasonable jurors could not. City of Keller v. Wilson, 168 S.W.3d 802, 823 (Tex.

2005). The final test for legal sufficiency must always be whether the evidence at trial

would enable reasonable and fair-minded people to reach the verdict under review. Id.

at 827. In our determination, we must uphold the jury's finding if more than a scintilla of

competent evidence supports it. "No evidence" points must only be sustained when the

                                              8
record discloses one of the following situations: (a) a complete absence of evidence of

a vital fact; (b) the court is barred by rules of law or of evidence from giving weight to the

only evidence offered to prove a vital fact; (c) the evidence offered to prove a vital fact is

no more than a mere scintilla; (d) the evidence establishes conclusively the opposite of

the vital fact. Id. at 810; King Ranch, Inc. v. Chapman, 118 S.W.3d 742, 751 (Tex.

2003), cert. denied, 541 U.S. 1030, 124 S. Ct. 2097, 158 L. Ed. 2d 711 (2004).

       In this case, the jury questions submitted track the Texas Pattern Jury Charge

recommended for a breach of contract case. Comm. On Pattern Jury Charges, State

Bar of Tex., Texas Pattern Jury Charges - Business, Consumer, Insurance &

Employment PJC 101.2 (2008). The instructions following the submission of questions

one and two also roughly follow the instructions contained in PJC 101.22 pertaining to

excused performance due to a material breach of contract. Id. at 101.22. Neither

question asked the jury to make a finding on the issue of "substantial performance."

Nevertheless, Another Attic contends the trial court erred in denying its motion for

judgment non obstante veredicto because various defects impaired the structure as a

whole, preventing a finding of substantial performance as a matter of law. However,

under the theory of liability submitted to the jury, substantial performance was not a vital

fact. Having chosen to submit the issue to the jury as a straight breach of contract

case, Another Attic cannot now complain that the trial court erred in somehow not

applying a theory of recovery not presented to the jury.

       As stated above, the liability issue was submitted to the jury by asking two basic

questions: (1) did Another Attic fail to comply with the contract, and (2) did Plains

                                              9
Builders fail to comply with the contract? In this case, the jury was presented with

evidence pertaining to alleged defects or omissions in seven particular areas: (1) the

location of steel in the concrete, (2) the adequacy of the concrete finish work, (3)

whether a cross walk was in violation of the Texas Accessibility Standards, (4) whether

a portion of the finished building lies within a 100-year flood plain, (5) whether the

appropriate insulation was installed, (6) the installation of a security gate, and (7)

completion of landscaping.     The jury was presented with evidence from both lay

witnesses and experts concerning the existence and materiality of each of these alleged

defects. The jury was also presented with testimony concerning the value of the work

not performed.

      As the issue was framed, based on the evidence presented, the jury could have

reasonably concluded that: (1) the alleged defects were not material, (2) Another Attic

was not justified in repudiating the contract, (3) Another Attic's termination of the

contract was a material breach of its obligations under the contract, (4) Plains Builders

was thus prevented from completing the remainder of its obligations under the contract,

(5) Another Attic's breach excused Plains Builders from further performance, and (6)

Plains Builders had allowed an appropriate credit for work not completed. Accordingly,

the record contains legally sufficient evidence to support the jury's liability findings.

Issue one is overruled.

                                           10
                                   Issues Two - Four

       By its next three issues, Another Attic essentially contends the trial court erred by

either submitting questions one and two, or by accepting the jury's verdict thereto

because the findings are not supported by legally or factually sufficient evidence. As

stated above, we have already found that the evidence supporting the jury's liability

findings is legally sufficient.

       An assertion that the evidence is factually insufficient to support a fact finding

means that the evidence supporting the finding is so weak or the evidence to the

contrary is so overwhelming that the answer should be set aside and a new trial

ordered.    Garza v. Alviar, 395 S.W.2d 821, 823 (Tex. 1965).         In reviewing factual

sufficiency, the reviewing court must consider, examine, and weigh all of the evidence in

the record. Maritime Overseas Corp. v. Ellis, 971 S.W.2d 402, 406-07 (Tex. 1998), cert.

denied, 525 U.S. 1017, 119 S. Ct. 541, 142 L. Ed. 2d 450 (1998). In doing so, the court

no longer considers the evidence in the light most favorable to the jury's finding; instead,

the court considers and weighs all the evidence and sets aside the disputed finding only

if it is so contrary to the great weight and preponderance of the evidence as to be

clearly wrong and unjust. Id. at 407; Gooch v. American Sling Co., 902 S.W.2d 181,

183-84 (Tex.App.BFort Worth 1995, no writ).

       Having reviewed the evidence in the light most favorable to the judgment, we

cannot say that reasonable and fair-minded people could not have reached the verdict

in question. Furthermore, having reviewed the evidence in a neutral light, we cannot

                                            11
say that the disputed findings are so contrary to the great weight and preponderance of

the evidence as to be clearly wrong or unjust. Accordingly, we conclude the evidence

was both legally and factually sufficient to support the jury's affirmative finding as to

Another Attic's breach and its negative finding as to Plains Builders's breach. Issues

two, three, and four are overruled.

                                      Issue Five

      By its fifth issue, Another Attic contests the legal sufficiency of the jury's

determination of damages. Specifically, Another Attic contends there was no evidence

regarding the cost of remediating the "admitted defects." Another Attic contends that

when a contractor seeks recovery on a substantial performance theory, the contractor

has the burden to prove the reasonable cost of remedying the defects or omissions

necessary to constitute complete performance.       Again, Another Attic's argument is

erroneously predicated on the assumption that Plains Builders's theory of recovery was

based upon the equitable doctrine of substantial performance.

      Where, as here, the jury found that Plains Builders did not breach its contractual

obligation in any material fashion; Plains Builders did not have the burden to prove the

reasonable cost of remediating any alleged defects. Plains Builders was entitled to

recover the full unpaid contract price, less the value of any work not completed due to

Another Attic's initial breach of contract by wrongfully preventing full performance.

Because evidence was presented concerning the value of work not completed, Plains

                                           12
Builders met its burden to establish it damages under the theory of recovery presented.

Issue five is overruled.

                                               Issue Six

       By its sixth issue, Another Attic contends the trial court erred in finding the
contract in question to be unambiguous on the issue of the insulation specifications.3
The only provision in the construction contract signed by the parties pertaining to
insulation provides as follows:

        All roof and separation walls in the dust control areas will be insulated with
        3" fiberglass insulation with UL flamespread vapor barrier.

Based on an exchange of pre-contract negotiation letters, Another Attic contends the

contract was ambiguous because its contracting agent was operating under the belief

that certain specifications were incorporated into the contract. Specifically, Another

Attic contends the contract incorporated language contained in a letter from DCD

Services, Inc. to Another Attic, which included the language "Insulation: 3" VRR in roof

only". The trial court ruled that the construction contract was not ambiguous and denied

Another Attic's requested charge regarding the ambiguity question.

        Whether or not a contract is ambiguous is a question of law to be reviewed by an

appellate court pursuant to a de novo review. Kothmann v. Rothwell, 280 S.W.2d 877,

879 (Tex.App.--Amarillo 2009, no pet.). In conducting a de novo review, we exercise

our own judgment and determine each legal issue. Id. If the written agreement is so

3
 In both its Statement of the Case and Summary of Argument, Another Attic references two alleged items
of ambiguity in the contract: (1) the insulation specifications and (2) the gate operating system. Because
Another Attic's brief presents no arguments and no record references to any ambiguity concerning the
gate operating system, that argument is inadequately briefed and is, therefore, waived. See Tex. R. App.
P. 38.1(h); White v. Baptist St. Anthony's Hosp., 188 S.W.3d 373, 374 (Tex.App.--Amarillo 2006, pet
denied).
                                                   13
worded that it can be given a certain or definite legal meaning or interpretation, then it is

not ambiguous and the court will construe the contract as a matter of law. Coker v.

Coker, 650 S.W.2d 391 (Tex. 1983).         Here, the contractual provision pertaining to

insulation, as set forth above, is subject to one clear, certain and definite meaning or

interpretation.   Accordingly, the trial court did not err in finding the contract to be

unambiguous as it pertains to the insulation specifications. Issue six is overruled.

                                       Issue Seven

       By its seventh issue, Another Attic contends the trial court erred by failing to

submit to the jury its questions pertaining to Plains Builders's contractual warranty and

its duty to supervise and perform the contract in a good and workmanlike manner.

During the charge conference, Another Attic's attorney objected to the trial court's

refusal to submit additional instructions following Question No. Six.           Specifically,

Another Attic argued that the court's charge should contain language from the contract

regarding Plains Builders's warranty obligation to replace any defective materials and

that the failure to include that language would improperly prevent the jury from

considering the labor costs incident to replacement of defective materials.

       The jury's obligation to answer Question No. Six was specifically predicated on

an affirmative answer to Question No. Two regarding whether or not Plains Builders had

materially breached its obligations under the construction contract. Because the jury

answered Question No. Two, "No," it did not answer Question No. Six. Therefore, any

                                             14
error in refusing Another Attic's requested instructions following Question No. Six would

have been harmless. See Tex. R. App. P. 44.1(a). Issue seven is overruled.

                                              Issue Eight

        By its eighth and final issue, Another Attic contends the trial court erred in

awarding attorney's fees when there was no evidence submitted regarding the

qualifications and nature of work performed by two paralegals/legal assistants assisting

Plains Builders's attorney, for which recovery was granted. Specifically, Another Attic

contends that the award of attorney's fees should be reduced by $3,086.25, because

there was no evidence presented pertaining to the work performed by the two

paralegals/legal assistants other than their hourly rate and number of hours expended.4

        An award of attorney's fees may include a legal assistant's time to the extent that

the work performed "has traditionally been done by an attorney." All Seasons Window

& Door Mfg. v. Red Dot Corp., 181 S.W.3d 490, 504 (Tex.App.--Texarkana 2005, no

pet.) (quoting Clary Corp. v. Smith, 949 S.W.2d 452, 469 (Tex.App.--Fort Worth 1997,

writ denied)). To recover attorney's fees for work performed by legal assistants, "the

evidence must establish: (1) the qualifications of the legal assistant to perform

substantive legal work; (2) that the legal assistant performed substantive legal work

under the direction and supervision of an attorney; (3) the nature of the legal work

performed; (4) the legal assistant's hourly rate; and (5) the number of hours expended

by the legal assistant." All Seasons Window & Door Mfg., 181 S.W.3d at 504 (quoting

4
 The statements attached to the Affidavit in Support of Plaintiff's Attorney's Fees submitted to the trial
court include entries for paralegal/legal assistants, C. Y. Hopkins and R. J. Brashears, totaling $3,067.50
and $18.75, respectively. The affidavit does not otherwise discuss their qualifications or the work done.
                                                   15
Multi-Moto Corp. v. ITT Commercial Fin. Corp., 806 S.W.2d 560, 570 (Tex.App.--Dallas

1990, writ denied)).

       Plains Builders contends that, because the issue of attorney's fees was a matter

submitted to the trial court for determination under the broad discretion afforded a trial

court pursuant to section 38.004 of the Texas Civil Practices and Remedies Code, the

award should be affirmed because it may be presumed that the court took judicial notice

of usual and customary attorney's fees in making its award. See Lee v. Perez, 120
S.W.3d 463, 469 (Tex.App.--Houston [14th Dist.] 2003, no pet.). While section 38.004

may permit a judge to take judicial notice of usual and customary attorney's fees, it does

not permit a judge to take judicial notice of the qualifications of a particular

paralegal/legal assistant to perform substantive legal work, or whether that

paralegal/legal assistant actually performed work traditionally performed by an attorney.

Accordingly, we modify the judgment to reduce the attorney's fees awarded to Plains

Builders by the sum of $3,086.25.

                                      Conclusion

       Having overruled issues one through seven and having modified the judgment to

reduce the recovery of attorney's fees pursuant to issue eight; the judgment of the trial

court is affirmed as modified.

                                                 Per Curiam

                                           16