Court Opinion

ID: 4507644
Source: CourtListenerOpinion
Date Created: 2020-02-14 13:11:32.222039+00
Date Added: 2024-06-11T08:52:54.016622
License: Public Domain

In The
                              Court of Appeals
                     Seventh District of Texas at Amarillo

                                   No. 07-19-00242-CV

             RUDY ALVAREZ, D/B/A/ ACOUSTICAL PLUS, APPELLANT

                                           V.

                             PATSY SHEPARD, APPELLEE

                     On Appeal from 72nd District Court, Lubbock, Texas
               Trial Court No. 2017528531, Honorable Kelly Moore, Presiding

                                   February 12, 2020

                            MEMORANDUM OPINION
                     Before QUINN, C.J., and PARKER and DOSS, JJ.

      This is an appeal from a final judgment awarding Patsy Shepard treble damages

against the appellant, Rudy Alvarez, d/b/a Acoustical Plus. Shepard contracted with

Alvarez to perform rather major improvements on two homes. She lived in one along with

her mother. The other home was that of her sister who happened to live next door.

Shepard obligated herself to pay for all construction being undertaken. Furthermore,

Alvarez accepted payment, began the work, failed to complete the renovations after

repeatedly being asked and promising to finish, and left the home in disrepair. That

resulted in Shepard suing him and alleging that he breached their contract, breached both
express and implied warranties regarding his services, and engaged in deceptive trade

practices. Trial was to the court, which found for Shepard and awarded her trebled

economic damages. Alvarez appealed. His sole issue concerns the award of treble

damages and whether sufficient evidence appeared of record illustrating that he acted

with the requisite mens rea to permit them. We affirm.

       The Texas Business and Commerce Code permits a consumer to maintain an

action when a breach of either an expressed or implied warranty is a producing cause of

damages. TEX. BUS. & COM. CODE ANN. § 17.50(a)(2) (West 2011). A consumer who

prevails may recover “economic damages” which may be trebled if the defendant

knowingly committed the misconduct. Id. § 17.50(b)(1). Furthermore, the legislature

explained that a breach of expressed or implied warranty is knowingly committed when

done with “actual awareness of the act, practice, condition, defect, or failure constituting

the breach.” Id. § 17.45(9). And, “actual awareness may be inferred where objective

manifestations indicate that a person acted with actual awareness.” Id.

       Next, implied within a contract to repair goods or property is a warranty to perform

those repairs in a good and workmanlike manner. Melody Home Mfg. Co. v. Barnes, 741
S.W.2d 349, 354 (Tex. 1987). Breaching it is actionable under § 17.50 of the Business

and Commerce Code. Id.; Cont’l Dredging, Inc. v. De-Kaizered, Inc., 120 S.W.3d 380,

390–91 (Tex. App.—Texarkana 2003, pet. denied). Most importantly, one’s failing to

complete work required under an agreement constitutes such a breach. Barnett v.

Coppell N. Tex. Court, Ltd., 123 S.W.3d 804, 823 (Tex. App.—Dallas 2003, pet. denied);

Cont’l Dredging, Inc., 120 S.W.3d at 391; LaBella v. Charlie Thomas, Inc., 942 S.W.2d
127, 135 (Tex. App.—Amarillo 1997, writ denied). Indeed, it seems rather logical that

                                             2
finishing the project is integral to a contractor’s duty to perform in a good and workmanlike

manner. With this, we turn to the record at bar.

       Within it lies evidence of Alvarez agreeing to perform the home renovations,

starting them, deconstructing portions of the Shepard home, and then leaving the abode

in a state of disrepair. To that we add evidence of Shepard’s queries about the slow

progress of his work, her requests for him to finish, his representations that he would

resume work, and his ultimate failure to complete the promised work.

       As Shepard testified to:

       And one time in March when I gave the check we got a bad storm . . . the house
       was so bad. It was raining in the house, electric wires [were] everywhere. I did
not    know what to do. I kept calling him. I could not get him. Me and my mom had to
       sleep. We [were] so scared. I could not sleep the whole night. And I’m like, I’ve
       got to go to work. I had pots, buckets, everything in the house. This is where he
       said the roof was fixed. He took the main beam out of the house. Water was all
       over the house. Water was just everywhere.

       “[F]inally in May,” she “couldn’t take it anymore” and encountered Alvarez in a store

or mall. He again promised that he was “going to be at [her] house next week” and

explained that he “got caught up on another job.” She added that before contracting with

Alvarez, she queried whether he had other jobs that would prevent him from performing

the renovations in a timely manner. He “guaranteed” her that he had none. Yet, he not

only “picked up other jobs to work on” while her “house [was] not even finished” but also

never returned to finish hers. And, by that time, Shepard had paid him $41,500 of the

$44,000 contract price.

       That he began the work, demanded and received at least 94% of the contract price

from Shepard, left the job, promised to return to finish the renovations, and never

completed them is evidence permitting the fact-finder to award treble damages. That is,

                                             3
leaving the job incomplete is some evidence from which a reasonable, fair-minded fact-

finder may rationally deduce that Alvarez breached his implied duty to act in a good and

workmanlike way. His having promised, in response to Shepard’s entreaties, to return

and finish the renovations is some evidence from which a reasonable and fair-minded

fact-finder may rationally deduce that he was actually aware of the “failure constituting

the breach,” which was his leaving the job incomplete. See City of Keller v. Wilson, 168
S.W.3d 802, 827 (Tex. 2005) (stating that the test for whether the verdict is supported by

legally sufficient evidence is whether the evidence at trial would enable reasonable and

fair-minded people to reach the verdict under review). And, with that evidence, the trial

court had legitimate bases to conclude that he acted knowingly and, therefore, treble the

economic damages suffered by Shepard.

       Though not substantively briefed, Alvarez also complains about the absence of

any finding from the trial court that he acted intentionally or knowingly when breaching

the implied warranty at issue. Yet, within its final judgment, the trial court found not only

that Shepard “is a consumer as defined under the Texas Deceptive Trade Practices

Consumer Protection Act (DTPA)” but also that “Defendant’s breaches of warranty are

deceptive trade practices committed knowingly and intentionally by Defendant.” Including

findings of fact in a judgment is improper when the litigants formally request such findings

and conclusions of law. Hill v. Hill, 971 S.W.2d 153, 156 (Tex. App.—Amarillo 1998, no

pet.). But, if they nonetheless appear in a judgment, they “have probative value as long

as they do not conflict with those in a separate document.” Id. at 157; accord S. Plains

Lamesa R.R. v. Heinrich, 280 S.W.3d 357, 365 (Tex. App.—Amarillo 2008, no pet.)

(recognizing the continued validity of the holding in Hill). Because the record does not

                                             4
contain either a request by anyone for findings of fact and conclusions of law or a

document apart from the judgment containing such findings and conclusions, those in the

judgment control.

      We overrule appellant’s issue and affirm the final judgment.

                                                      Brian Quinn
                                                      Chief Justice

                                           5