Court Opinion

ID: 2679446
Source: CourtListenerOpinion
Date Created: 2014-06-19 01:26:09.917689+00
Date Added: 2024-06-11T13:11:54.353525
License: Public Domain

Illinois Official Reports

                                         Appellate Court

        GK Development, Inc. v. Iowa Malls Financing Corp., 2013 IL App (1st) 112802

Appellate Court              GK DEVELOPMENT, INC., an Illinois Corporation, and COLLEGE
Caption                      SQUARE MALL DEVELOPMENT, LLC, a Delaware Limited
                             Liability Company, Plaintiffs-Appellees, v. IOWA MALLS
                             FINANCING CORPORATION, a Delaware Corporation, COLLEGE
                             SQUARE MALL ASSOCIATES, LLC, a Delaware Limited Liability
                             Company, and CHICAGO TITLE AND TRUST COMPANY, an
                             Illinois Corporation, Defendants-Appellants.

District & No.               First District, Fourth Division
                             Docket Nos. 1-11-2802, 1-12-0432 cons.

Filed                        December 19, 2013

Held                         In an action arising from plaintiffs’ purchase of several shopping
(Note: This syllabus         centers from defendants for $117 million, the appellate court reversed
constitutes no part of the   the trial court’s order awarding plaintiffs $4.3 million placed in
opinion of the court but     escrow pursuant to the parties’ agreement that the money would go to
has been prepared by the     plaintiffs if a current tenant did not complete its expansion into a
Reporter of Decisions        recently vacated space by a certain deadline, but would go to
for the convenience of       defendants if the move was completed on time, since the agreement
the reader.)                 was an invalid and unenforceable penalty clause that did not satisfy
                             the requirements of Jameson, the agreement gave plaintiff buyer a
                             windfall, and it functioned as a penalty for nonperformance because
                             the penalty was not related to any actual damages; furthermore, the
                             appellate court remanded the cause with directions to allow the trial
                             court to hear evidence as to whether plaintiffs suffered any actual
                             damages as a result of the tenant’s 91-day delay in completing its
                             move and to award plaintiffs those damages out of the escrowed
                             funds, with the balance going to defendants, and the trial court was
                             also directed to determine whether there was any breach by plaintiffs
                             that would entitle defendants to an award of court costs and attorney
                             fees.
     Decision Under           Appeal from the Circuit Court of Cook County, Nos. 06-CH-3427,
     Review                   06-CH-3586 cons.; the Hon. Carolyn Quinn, Judge, presiding.

     Judgment                 Affirmed in part and reversed in part with instructions.

     Counsel on               Kent Maynard, Jr., and Heather Nicole Koffman, both of Kent
     Appeal                   Maynard & Associates LLC, of Chicago, for appellants.

                              J. Timothy Eaton and Jonathan B. Amarilio, both of Shefsky &
                              Froelich Ltd., of Chicago, for appellees.

     Panel                    PRESIDING JUSTICE HOWSE delivered the judgment of the court,
                              with opinion.
                              Justices Fitzgerald Smith and Lavin concurred in the judgment and
                              opinion.

                                             OPINION

¶1         The issue presented in this case is whether a provision in a contract for the sale of four
       shopping centers, which required that $4.3 million of the purchase price be held in escrow from
       the seller’s proceeds then be paid to the seller only if certain conditions are timely met, is
       enforceable as a liquidated damages clause or is unenforceable as a penalty.
¶2         In a $117 million transaction, plaintiffs GK Development, Inc., and College Square Mall
       Development, LLC (collectively Buyer), purchased from defendants Iowa Malls Financing
       Corporation and College Square Mall Associates, LLC (collectively Seller), four shopping
       centers in eastern Iowa, including College Square Mall (Mall). Prior to the sale, Mall tenant
       Hy-Vee Food Stores, Inc. (Hy-Vee), was in the process of expanding its grocery store (Hy-Vee
       Expansion) into the space that had been vacated by Wal-Mart after Wal-Mart decided not to
       renew its lease. Because the parties did not expect the Hy-Vee Expansion to be completed by
       the time of the closing, Buyer and Seller negotiated to hold $4.3 million of the purchase price
       in escrow (Hy-Vee Holdback), which represented the present value of the leasehold with
       regard to the forthcoming Hy-Vee Expansion.
¶3         An amendment to the purchase agreement directed defendant Chicago Title and Trust
       Company (the Escrowee) to release the Hy-Vee Holdback to Seller only after and if all the
       following events occurred: (1) a new Hy-Vee lease was executed by August 31, 2005; (2) the

                                                  -2-
     new Hy-Vee leasehold was delivered by Buyer and accepted by Hy-Vee before October 31,
     2005; and (3) Hy-Vee obtained all permits and other governmental approvals necessary to
     complete the Hy-Vee Expansion prior to October 31, 2005. Hy-Vee did not obtain the
     necessary permits before October 31, 2005; however, both parties demanded that the Escrowee
     disperse the Hy-Vee Holdback in their favor. Both Buyer and Seller subsequently filed
     separate lawsuits seeking a declaratory judgment regarding their entitlement to the Hy-Vee
     Holdback, and the two lawsuits were consolidated into the instant action. Following a
     three-week bench trial, the trial court found that the parties intended a “drop-dead deadline” of
     October 31, 2005 for plan and permit approval, and that Buyer was entitled to the Hy-Vee
     Holdback as liquidated damages for a breach of contract. The trial court also granted Seller’s
     posttrial motion to “Stay Enforcement of the Circuit Court’s order and Judgment and Not
     Apply Post-Judgment Interest During Appeal.” Both parties appealed, and those appeals were
     consolidated.
¶4       Within Seller’s appeal (appeal No. 1-11-2802), Seller argues: (1) that the Hy-Vee
     Holdback is not a valid liquidated damages provision because it amounts to an unenforceable
     penalty clause; (2) that the trial court erred in finding the parties’ agreement ambiguous; (3)
     that the trial court’s interpretation of the parties’ contract violates Illinois rules of contract
     construction; and (4) that the trial court erred as a matter of law in failing to award attorney fees
     to Seller. In response, Buyer claims: (1) that the Hy-Vee Holdback is a valid and enforceable
     liquidated damages provision as construed by the trial court; (2) that the trial court’s finding
     that the contract terms were ambiguous and required extrinsic evidence to interpret the parties
     intent was reasonable; (3) that Seller forfeited several of its arguments concerning the trial
     court’s contract interpretation; and (4) that Seller is not entitled to attorney fees. Within
     Buyer’s appeal (appeal No. 1-12-0432), Buyer argues that the trial court’s order denying Buyer
     postjudgment interest must be reversed. For the following reasons, we reverse the trial court’s
     order directing the $4.3 million be returned to the Buyer because we find that the contract
     provision under review is unenforceable as a penalty clause.

¶5                                    I. BACKGROUND
¶6       In 2004, Seller owned four shopping malls in eastern Iowa, which included College Square
     Mall (Mall) in Cedar Falls, Iowa. Wal-Mart and Hy-Vee were among the larger “anchor”
     stores in the Mall. The Wal-Mart occupied 160,128 square feet of space, while the Hy-Vee
     occupied a smaller, 59,860-square-foot building adjacent to it. Hy-Vee’s original lease began
     in 1976 and was due to expire on December 31, 2010, subject to three, five-year renewal
     options. The lease provided that Hy-Vee pay a $26,166.67 monthly rent ($314,000 annum, or
     $5.25 per square foot) from January 1, 2006, through December 31, 2010. In addition to this
     base rent, Hy-Vee paid a pro rata share of real estate taxes and common area maintenance
     (CAM).

¶7                                    A. The Purchase Agreement
¶8       Prior to trial, the parties stipulated to the following in a joint statement of agreed facts.

                                                   -3-
¶9         In June 2004, Seller began marketing the Mall for sale and issued an offering
       memorandum, which opined that Hy-Vee would relocate to a larger leasehold of 75,000 square
       feet in Wal-Mart’s former space. The Hy-Vee Expansion would increase its rented square
       footage by 15,000 square feet at a cost of $6 per square foot, and the former Hy-Vee space
       would be divided to accommodate “two new big box anchors.” The memorandum
       contemplated that Hy-Vee would execute a new 60-month lease by March 2005. Buyer then
       entered into discussions with Seller to purchase the Mall.
¶ 10       In July 2004, Buyer executed a letter of intent to purchase the Mall, as well as the three
       other Iowa malls, for $117 million. On September 17, 2004, Buyer and Seller entered into a
       real estate sales contract (Purchase Agreement) to purchase the four malls, and set a closing
       date of December 17, 2004.
¶ 11       On October 12, 2004, Hy-Vee executed a letter of intent (Letter of Intent) to open a “first
       class high quality Hy-Vee retail grocery store,” which is described as a “21st century
       prototype,” in the space formerly occupied by Wal-Mart. The Letter of Intent contemplated
       that Hy-Vee would lease 78,337 square feet for a minimum term of 20 years, followed by five,
       five-year renewal options. The initial base rent would be $7 per square foot and would
       incrementally rise to $9.35 per square foot beyond the initial 20-year term. In addition to the
       base rent, Hy-Vee would pay a certain pro rata share of the Mall’s real estate taxes and CAM.
       The parties agreed that the proposed Hy-Vee lease, which would increase the fair market value
       of the Mall, would not be executed prior to the closing on the sale of the Mall. Seller and
       Hy-Vee agreed that Hy-Vee would require 270 days to extensively remodel the new leasehold.
       The Letter of Intent indicated that Hy-Vee’s “possession date” would occur upon: (1)
       execution of the lease; (2) receipt of certain government approvals; and (3) delivery of the
       space from Buyer.
¶ 12       On October 26, 2004, Buyer’s primary negotiator, Thomas Rogers, sent a letter 1 to Seller’s
       broker, George Good of CB Richard Ellis, that outlined certain issues of concern. One issue of
       concern was the economic impact of the Hy-Vee Expansion because it was not expected that
       Hy-Vee would sign a new lease before the December 2004 closing. To calculate the present
       value of the Hy-Vee Expansion, Rogers determined that the new lease would generate a future
       incremental income of $430,000 per year. He next calculated that, based on a 10%
       capitalization rate, the present value of the 20-year Hy-Vee Expansion lease was $4.3 million.
       To resolve the uncertainty of the new lease’s impact on the $117 million sale, Rogers
       suggested that the $4.3 million be held back in escrow until: (1) the new lease was signed; (2)
       the supermarket was open for business: and (3) the leasehold was lien free.

¶ 13                                B. The Third Amendment
¶ 14       On November 10, 2004, Buyer and Seller entered into the “Third Amendment to Real
       Estate Sale Contract” (Third Amendment) to memorialize the parties’ holdback agreement.
       Accordingly, the Third Amendment provided that $4.3 million of the purchase price would be

          1
            Rogers’ letter was not included in the joint statement of facts; however, it was admitted into
       evidence at trial.
                                                    -4-
       held in escrow and released to Seller when and if: (1) Hy-Vee executes a new lease by August
       31, 2005; (2) Buyer delivers and Hy-Vee accepts the new leasehold by October 31, 2005; and
       (3) Hy-Vee obtains, by October 31, 2005, all permits and other governmental approvals
       necessary to complete the expansion. Specifically, the Third Amendment provides in relevant
       part:
               “With respect to [the Mall], [the Buyer] and the Seller of said Property agree that at
               Closing they will enter into a Four Million Three Hundred Thousand and 00/100 Dollar
               ($4,300,000.00) holdback agreement from the purchase price of said Property ***. The
               holdback amount shall not be released until all of the following are satisfied: (1)
               execution of the lease with Hy Vee, Inc. on terms in accordance with Letter of Intent,
               dated October 12, 2004, attached hereto as Exhibit C, and in a form that is
               commercially reasonable; (2) delivery of the premises to [Hy-Vee] in the condition
               required *** as specified in the lease; and (3) acceptance by [Hy-Vee] of the premises
               and the obtaining by [them] of all permits and other governmental approvals necessary
               to complete the tenant’s work. Should the lease not be executed by August 31, 2005, or
               all of the other conditions not be satisfied by October 31, 2005, the holdback amount
               shall not be released to the Seller, but it shall be forfeited and delivered to [the Buyer].”
¶ 15       Thomas Rogers, Buyer’s primary negotiator, testified that he negotiated the $4.3 million
       figure with Seller’s primary negotiator, Michael Fontana. Furthermore, Rogers testified that
       the October 31, 2005 deadline was proposed by Seller, which was corroborated by the
       testimony of Gerry Curciarello and Patrick O’Leary, co-managing partners of Seller.
       Curciarello also testified at trial that the $4.3 million figure and the October deadline were the
       products of an arm’s-length negotiation between Buyer and Seller, and that, at the time of the
       negotiations, he felt that the deadline was sufficiently distant to allow Seller to meet all of its
       obligations.

¶ 16                         C. The Deed and Money Escrow Agreement
¶ 17       Prior to closing, on December 15, 2004, Buyer and Seller entered into a “Deed and Money
       Escrow Agreement” (DME), as required by the Third Amendment. The DME instructed the
       Escrowee to release the Hy-Vee Holdback upon the completion of the following events: (1)
       execution of a new commercially reasonable lease in conformity with the Letter of Intent; (2)
       delivery of the space to Hy-Vee; (3) acceptance of the space by Hy-Vee; and (4) Hy-Vee’s
       receipt of all permits and other governmental approvals necessary for Hy-Vee to complete the
       expansion. Specifically, section VII of the DME, titled “Hy-Vee Holdback,” provides as
       follows:
               “At any time after the Closing Date that [the Seller] shall advise [the Escrowee], in
               writing, and under oath, that (a) a lease in a commercially reasonable form has been
               signed by Hy-Vee, Inc. (‘Hy-Vee’) for the space previously occupied at [the Mall] by
               Wal-Mart (‘the Hy-Vee Space’) substantially in accordance with the Letter of Intent
               dated October 12, 2004, (b) that the Hy-Vee Space has been delivered to Hy-Vee in the
               condition required by the terms of such lease, (c) that the tenant [Hy-Vee] thereunder
               has accepted the Hy-Vee Space and (d) that such tenant has obtained all government
                                                   -5-
               approvals and permits necessary for it to complete its work, then [the Escrowee] shall
               advise [the Buyer] in writing of such demand for payment and, unless [the Escrowee]
               receive objection in writing within five (5) days, the Hy-Vee Holdback shall be made to
               [the Seller]. If said objection is timely made, [the Escrowee is] to continue to hold the
               Hy-Vee Holdback subject to the joint direction of the parties or order of court.”
       Section VII further provides the following deadlines for these four events to occur:
               “In the event that the Seller is unable to deliver such a lease signed by Hy-Vee on or
               before August 31, 2005, or in the event the conditions of Subscriptions (b), (c) and (d)
               are not satisfied on or before October 31, 2005, without default of [the Buyer], then,
               and only in such event, the Hy-Vee Holdback shall be paid to [the Buyer]; provided,
               however, if the plans have not been finalized by reason of any delay in producing,
               approving or revising such plans (such delay to be determined in accordance with the
               terms of Hy-Vee’s lease), then, and in all such events, the October 31, 2005 date shall
               be extended by one day for each day of delay in the delivery plan approval. If [the
               Seller] shall notify Escrowee that it claims a delay and extension, Escrowee shall retain
               the Hy-Vee Holdback subject to a joint direction of the parties or an order of the court.”
       Curciarello testified that, at the time the DME was executed, he still believed that the October
       31, 2005 deadline was sufficiently distant to allow Seller to complete all of its obligations.
¶ 18       Section VII also provides that Buyer will perform certain parking lot improvements and
       that Seller will later reimburse Buyer for the construction costs. If the parking lot
       improvements are the sole reason for Hy-Vee not fulfilling its obligations prior to the October
       31, 2005 deadline, then Seller will not be determined to have failed to meet the deadline. In
       such event, 105% of the parking lot construction costs (determined by competitive bidding)
       will be paid to Buyer out of the Hy-Vee Holdback, and the remainder of the Hy-Vee Holdback
       will be released to Seller.

¶ 19                                  D. The New Hy-Vee Lease
¶ 20       Closing took place on December 17, 2004, and Buyer purchased the four Iowa malls for
       $117 million, including the Mall, which accounted for $38.5 million of the purchase price. The
       Mall was divided into two parcels: parcel 1, which was valued at $33.5 million and included
       the entire Mall property except for the Hy-Vee and former Wal-Mart leaseholds, and parcel 2,
       which was valued at $5 million and included only the Hy-Vee and former Wal-Mart
       leaseholds. Of the $5 million paid for parcel 2, $4.3 million was held in escrow pending the
       requirements laid out in the Third Amendment and DME.
¶ 21       After closing, Seller engaged Hy-Vee in negotiating a new lease. While the new lease was
       being negotiated, Seller contracted and paid for an asbestos abatement in the former Wal-Mart
       space, which was completed in June 2005. Hy-Vee signed the new lease (Hy-Vee Lease) on
       June 16, 2005. The Hy-Vee Lease provided for 79,750 square feet of the former Wal-Mart
       space at a price of $7 per square foot, and contemplated a minimum 20-year term, followed by
       five successive five-year options, which would run for a total term of 45 years. The Hy-Vee
       Lease provided that the original Hy-Vee store would operate while the new leasehold was

                                                   -6-
       remodeled and that the 20-year term would begin to run on the date of possession, with rent
       becoming due on the rent commencement date.
¶ 22       Upon receiving the Hy-Vee Lease, Buyer requested that Hy-Vee make two revisions.
       Although Hy-Vee refused to make the suggested revisions, Buyer signed the Hy-Vee Lease on
       July 15, 2005.
¶ 23       Section 3(A) of the Hy-Vee Lease provides that Hy-Vee has 75 days following the
       execution of the lease, or until September 28, 2005, to submit “detailed plans and
       specifications for the Hy-Vee Expansion” to Buyer for approval. Buyer would then have 10
       business days to approve the plans. If Buyer disapproves of the final plans, then Hy-Vee would
       have until 10 business days thereafter to submit revised plans, followed by an additional 7
       business days for Buyer to approve them. More specifically, section 3(A)(1) provides in
       relevant part:
                   “(1) Plans and Approvals. Landlord [the Buyer] and Tenant [Hy-Vee] have
               reviewed and approved Tenant’s preliminary site plan for the Hy-Vee Expansion
               attached hereto as Exhibit B (the ‘Site Plan’). On or before the 75th day following the
               date of this lease, Tenant at its expense shall submit to Landlord detailed plans and
               specifications for the Hy-Vee Expansion (the ‘Final Plans and Specifications’),
               prepared by Tenant for Landlord’s approval, which approval Landlord shall not
               unreasonably withhold, condition or delay. *** Landlord shall within ten (10) business
               days after receipt of all of said Final Plans and Specifications notify Tenant in writing
               of its approval or disapproval thereof, with any such disapproval to be specifically
               explained. If Landlord does not approve the Final Plans and Specifications as initially
               submitted, Tenant shall within ten (10) business days thereafter submit for approval
               revised Final Plans and Specifications addressing any objections. Landlord shall then
               have seven (7) business days after receipt of said revised Final Plans and Specifications
               to approve or disapprove same.”
       Also, section 3(A)(1) of Hy-Vee Lease (titled “Plans and Approvals”) provides certain
       “Construction Conditions” that must be met. Subsection (a) provides for the mutual agreement
       between Buyer and Hy-Vee on final plans and specifications within the time frame set forth in
       section 3(A)(1). Subsection (d) provides that Hy-Vee must promptly submit an application for
       building permits, and that it shall obtain those permits and other governmental approvals
       within 30 days after Buyer’s approval of the final plans and specifications. Subsection (d) also
       contains a delay provision, which provides that if Hy-Vee submits permit applications and
       diligently pursues obtaining them prior to the deadline, then it could, upon its written request,
       obtain a 60-day extension. Specifically, section 3(A)(1) of the Hy-Vee Lease provides the
       following construction conditions:
               “The construction of the Hy-Vee Expansion shall be further subject to the satisfaction
               of the following conditions (the ‘Construction Conditions’):
                   (a) The mutual agreement of Landlord and Tenant to the plans and specifications
               for the Hy-Vee Expansion, as provided and within the time parameters set forth in
               Section 3(A)(1);

                                                   -7-
                                                    ***
                    (d) Tenant agrees to promptly submit an application for building permits and shall
                obtain all such permits and other governmental authorizations (the ‘Government
                Approvals’) required for construction of the Hy-Vee Expansion within thirty (30) days
                after the Landlord’s approval of Tenant’s Final Plans and Specifications;; [sic]
                provided, however, if Tenant timely submits such permit applications and diligently
                pursues obtaining such permits, upon the written request of Tenant, Tenant may obtain
                a sixty (60) day extension of the Construction Condition set forth in this subsection
                3(A)(1)(d).”
       It is undisputed that Hy-Vee did not make a written request to Buyer for an extension, and that
       Buyer did not notify Hy-Vee of any default under the Hy-Vee Lease.
¶ 24        Furthermore, section 3(A)(1) provides that Buyer has 120 days following the execution of
       the lease, or until November 13, 2005, to reach an agreement with Hy-Vee on the final plans
       and specifications, and if not, then Hy-Vee would have the option to abandon the expansion
       and remain on its original lease, while the new Hy-Vee Lease would be rendered void. Section
       3(A)(1) further provides in relevant part:
                “Tenant shall provide written notice to Landlord when all of the Construction
                Conditions have been satisfied and/or waived ***. In the event that (I) the Construction
                Condition set forth in subparagraph (a) is not satisfied within one hundred and twenty
                (120) days following the date of this Lease; *** or (iv) the Construction Condition set
                forth in subparagraph (d) is not satisfied within 30 days after Landlord approves the
                Tenant’s plans and specifications (or 90 days if extended for the additional 60-day
                period as provided above), are not satisfied and/or waived by Tenant within (w) the
                120-day period as to clause (I) set forth above, *** and (z) the 30-day period (or 90-day
                period, if extended the additional 60-day period) as to clause (iv) set forth above,
                Tenant may, as Tenant’s sole and exclusive remedy, elect to terminate this lease by
                written notice delivered to Landlord on or before the expiration of (w) the 120-day
                period as to clause (I) set forth above, *** and (z) the 30-day period (or 90-day period,
                if extended the additional 60-day period) as to clause (iv) set forth above and, in such
                case, the Old Lease shall remain in full force and effect. If Tenant does not give such
                termination notice ***, this lease shall remain in full force and effect and the Old Lease
                shall be deemed to be terminated as provided in Section 52 hereof.”
       Hy-Vee submitted its final plans and specifications to Buyer on the September 28, 2005
       deadline. Ten business days later, Buyer disapproved the plans and requested Hy-Vee to make
       certain revisions. On October 31, 2005, or 13 business days later, Hy-Vee submitted its revised
       final plans and specifications. October 31, 2005 was also the deadline set forth in the Third
       Amendment and the DME for Hy-Vee to obtain building permits and other government
       approvals, and Hy-Vee applied to the Cedar Falls building department for a construction
       permit and other necessary approvals on that day. Six business days later, on November 8,
       2005, Buyer approved Hy-Vee’s revised plans.

                                                    -8-
¶ 25        On November 2, 2005, Seller sent to Buyer a letter 2 proposing to extend the Third
       Amendment’s October 31, 2005 deadline to January 31, 2006. In addition to the extended
       deadline, Seller proposed that the Hy-Vee Holdback be released to Seller, less the cost Buyer
       spent on the construction of Hy-Vee’s new parking lot. Buyer responded on November 16,
       2005 with a counter proposal that contemplated an extended deadline in exchange for Seller
       paying Buyer for rent that would have been paid had the original deadline been met. According
       to Buyer, the rent that would have been paid was approximately $47,000 per month plus a
       pro rata share of real estate taxes and CAM. Additionally, Buyer proposed that if the new
       deadline were not met, Buyer would receive $100,000 per month from the Hy-Vee Holdback
       in lieu of rent payments. The negotiations did not advance past Buyer’s counteroffer, and the
       October 31, 2005 deadline was never extended.
¶ 26        On January 6, 2006, Buyer sent a letter to the Escrowee demanding that it release the entire
       $4.3 million Hy-Vee Holdback to Buyer because Seller did not meet the October 31, 2005
       deadline. Three days later, Seller sent the Escrowee a letter objecting to the release of the
       Hy-Vee Holdback to Buyer, requesting that the Escrowee retain the Holdback subject to joint
       direction of the parties or the receipt of a court order. Later that day, Buyer sent another letter
       to the Escrowee stating that it agreed that the Escrowee should retain the Hy-Vee Holdback
       until the dispute was resolved. On February 9, 2006, Seller sent another letter to the Escrowee
       demanding that it release the Hy-Vee Holdback to Seller because all of the conditions required
       for release of the funds had been met, except for the completion of the parking lot
       improvements. Seller demanded that the $200,000 cost of the parking lot construction be
       deducted from the Hy-Vee Holdback, and the remaining $4.1 million be released to Seller. On
       February 10, 2006 and February 14, 2006, Buyer sent letters to the Escrowee objecting to the
       release of the Hy-Vee Holdback, and requesting that the Escrowee continue to retain the
       Holdback until it received a joint direction from the parties or a court order.
¶ 27        On January 27, 2006, Hy-Vee obtained a construction permit from the City of Cedar Falls.
       Three days later, Buyer delivered the new space, which totaled 80,189 square feet, to Hy-Vee,
       and Hy-Vee accepted it and all necessary permits were obtained. Under the terms of the Lease,
       Hy-Vee was required to complete the construction on the expansion within the next 330 days.
       Hy-Vee’s acceptance of the premises also triggered its obligation to begin paying a pro rata
       share of the Mall’s real estate taxes and CAM, in addition to its share of the existing Hy-Vee
       leasehold. Hy-Vee would then begin paying a minimum fixed base rent of $46,521 per month
       within the next 270 days, or when the new Hy-Vee supermarket opened, whichever occurred
       first.

¶ 28                                  E. The Instant Litigation
¶ 29       On February 17, 2006, Buyer filed an action in the chancery division of the circuit court of
       Cook County against Seller and the Escrowee seeking declaratory judgment and specific
       performance, claiming that it was entitled to the $4.3 million Hy-Vee Holdback as liquidated

           2
            Though neither Seller’s proposal nor Buyer’s counterproposal was included in the joint statement
       of facts, both were admitted into evidence at trial.
                                                     -9-
       damages for Seller’s failure to fulfill its contractual obligations prior to the October 31, 2005
       deadline (case No. 06 CH 3427).
¶ 30       Seller also filed a suit in the chancery division on February 22, 2006 against Buyer seeking
       a declaratory judgment that it was entitled to the release of the entire Hy-Vee Holdback (case
       No. 06 CH 3586). Seller claimed that Hy-Vee’s failure to obtain the necessary building permits
       prior to October 31, 2005 did not amount to a contractual violation because the “provided,
       however” clause of the Hy-Vee Lease extended the deadline to February 12, 2006. Seller also
       claimed that Buyer breached the DME by claiming that Seller had not fulfilled its
       requirements.
¶ 31       The circuit court subsequently consolidated both lawsuits.
¶ 32       Buyer also filed a separate lawsuit (case No. 06 CH 26662) against Seller seeking the
       recovery of $530,294.86 from the Hy-Vee Holdback for the costs that it expended on the
       Hy-Vee parking lot construction.
¶ 33       While the litigation was pending, on November 16, 2006, Hy-Vee opened its new
       supermarket in the former Wal-Mart leasehold, and has since been making payments as
       required under the new Hy-Vee lease.
¶ 34       Seller moved for summary judgment on December 4, 2008, arguing that the clear and
       unambiguous language of the Hy-Vee Lease extended the deadline for Hy-Vee to obtain
       government approvals from October 31, 2005 to February 2006. In response, Buyer argued
       that only a delay by Buyer in the delivery of plan approvals could extend the deadline. The trial
       court denied Seller’s motion on April 9, 2009, finding that the provisions of the Third
       Amendment, DME, and Hy-Vee Lease, when read together, were “ambiguous as to whether
       the governmental approvals and authorizations [fell] within the delay provision of Section VII
       of the DME” because the terms “plans” and “plan approval” were not clearly defined or
       consistently used throughout the documents. The trial court stated that “it is not clear whether
       the October 31, 2005 deadline would be extended only for delays in approving the Plans and
       Specifications or for delays in approving the Plans and Specifications and obtaining the
       Government Approvals.” The case then proceeded to trial for a hearing of extrinsic evidence to
       resolve this contractual ambiguity.
¶ 35       At trial, the circuit court heard testimony from: Garo Khalamian, president and owner of
       GK Development, Inc.; David Sullivan, senior vice-president of development for Buyer;
       Michael Fontana, Seller’s senior property accountant; Gary Curciarello, co-managing partner
       of Seller; and Patrick O’Leary, co-managing partner of Seller along with Curciarello. It also
       reviewed evidentiary deposition testimony from: Thomas Rogers, Buyer’s primary negotiator;
       and David Bailey, assistant vice president, real estate, for Hy-Vee. In addition, the trial court
       considered the parties’ documentary evidence, such as the letters and emails exchanged
       between the witnesses.
¶ 36       At trial, the parties focused a great deal of time on the issue of whether the parties had
       intended a firm deadline of October 31, 2005 for Hy-Vee to obtain governmental approvals, or
       whether the date was an aspirational target for the Hy-Vee Expansion. O’Leary, Curciarello,
       and Fontana each testified that the October 31, 2005 deadline was a “target” or “place holder”

                                                  - 10 -
       date that was not intended to be rigidly enforced. On cross-examination, however, Curciarello
       admitted that in his prior deposition testimony he testified that the purpose of an October 27,
       2005 telephone conference involving himself, Garo, and Fontana was to extend the October 31
       deadline. Buyer also impeached Fontana’s testimony with a January 10, 2005 email sent to
       O’Leary and Curciarello in which Fontana wrote that “Our [the Seller’s] contract with GK [the
       Buyer] requires us to deliver the space to Hy-Vee with plans approved and permits issued by
       October 31, 2005, or forfeit the money held back.” Fontana wrote in an email that as long as
       the Hy-Vee Lease is executed by April 1, 2005, then it would be likely that the space would be
       delivered in time and “the seller will get the money held in escrow.” Moreover, Fontana also
       wrote in the email that Seller was protected by a clause that provides that “delays in the
       Hy-Vee planning/permitting process beyond the time periods set out in the lease that are
       caused by GK or Hy-Vee do not count against the seller.” Buyer further impeached Fontana’s
       testimony with a March 2, 2005 email in which Fontana wrote to Curciarello that Seller would
       be “in jeopardy” if the Hy-Vee Lease were not executed by April 12, 2005, because “the
       contract with GK requires *** the space to be delivered with all delivery conditions met by
       October 31.”
¶ 37        Following the three-week bench trial, in addition to the facts stipulated to by the parties, the
       trial court made additional findings of fact, which included:
                    “35. Seller negotiated the terms of the New Hy Vee Lease. Buyer was permitted to
                suggest Lease contents and did so, but Buyer had no right to dictate lease terms. None
                of the lease changes suggested by buyer concerned deadlines for submissions or
                approval of plans or permits.
                    36. If Buyer had refused to sign a lease that Seller deemed ‘commercially
                reasonable,’ Seller would have sued Buyer for breach of contract.
                    37. The New Hy Vee Lease contained time periods triggering obligations between
                landlord and tenant, but did not contain a terminal date for obtaining governmental
                permits.
                    38. Seller never told Hy Vee that the deadlines calculated in the New Hy Vee Lease
                needed to be shortened to comply with the October 31, 2005 deadline.
                    39. Buyer never indicated it was concerned about the schedule set forth in the Hy
                Vee Lease.
                    40. At the time the parties executed the Third Amendment and DME, Seller and
                Buyer believed that the New Hy Vee Lease would be executed prior to August 31,
                2005, and that the tenant could obtain pain approval and necessary permits by October
                31, 2005. Seller believed the lease would be negotiated no later than March, 2005. As
                late as March, 2005, Fontana believed a lease could be executed in April followed by
                approval and permitted plans by October 31, 2005. As of July 15, 2005, it was still
                possible that the October 31, 2005 deadline could be met.
                    41. When Buyer and Seller negotiated the Third Amendment and DME, they
                intended October 31, 2005, to be the deadline for Hy Vee to obtain plan approval and
                government permits.

                                                    - 11 -
                    42. The purpose of an October 27, 2005, telephone conference involving Garo,
                Fontana, Curciarello, Sullivan and Rogers was in part to negotiate an extension of the
                October 31, 2005, deadline set forth in the contract documents. At Buyer’s suggestion,
                Seller drafted a proposed extension of the October 31, 2005 deadline to January 31,
                2006. Buyer did not accept this proposed amendment.
                    43. The difference between the existing Hy Vee lease and the new Hy Vee lease
                was approximately $430,000.00 in additional annual income to the landlord (Buyer).
                The Hy Vee Holdback amount of $4,300,000.00 was a term negotiated by the parties
                and fairly represented the incremental value of the Hy Vee Lease.
                    44. By the October 21, 2004, LOI, Hy Vee proposed opening a ‘first class high
                quality Hy Vee retail grocery store’, a ‘21st century prototype’ in the 78,000 square
                feet space previously occupied by Wal Mart.
                    45. Hy Vee was one of the anchor stores at College Square Mall. Its existing space
                could be modified to house two new, additional anchor stores. An expanded Hy Vee
                was marketed as a draw for other retailers to the mall. The mall housed multiple tenants
                and could accommodate right ‘anchor spaces.’ ”
¶ 38        Based on the stipulated facts and the facts laid out above, the trial court found that the
       parties “intended October 31, 2005, to serve as the deadline for plan and permit approval,” and
       that Seller was in breach of contract because Hy-Vee did not obtain the necessary permits prior
       to October 31, 2005. The trial court further found that the Hy-Vee Holdback constituted a valid
       and enforceable liquidated damages clause, and it awarded the entire $4.3 million Hy-Vee
       Holdback to Buyer. The trial court also dismissed the related lawsuit in case No. 06 CH 26662
       as moot because any damages owed to Buyer for the parking lot construction would have been
       paid out of the Hy-Vee Holdback.
¶ 39        Seller appeals case Nos. 06 CH 3427 and 06 CH 3586, consolidated (appeal No.
       1-11-2802), claiming: (1) that the Hy-Vee Holdback is not a valid liquidated damages
       provision; (2) that the trial court erred in finding the parties’ agreement ambiguous; (3) that the
       trial court’s interpretation of the parties’ contract violates Illinois rules of contract
       construction; and (4) that the trial court erred as a matter of law in failing to award attorney fees
       to Seller. In response, Buyer claims: (1) that the Hy-Vee Holdback is a valid and enforceable
       liquidated damages provision; (2) that the trial court’s finding that the contract terms were
       ambiguous and required extrinsic evidence to interpret the parties’ intent was reasonable; (3)
       that Seller did not forfeit several of its arguments concerning the trial court’s contract
       interpretation; and (4) that Seller is not entitled to attorney fees.
¶ 40        The trial court later granted Seller’s posttrial motion to stay the enforcement of its
       judgment and ordered that postjudgment interest would not apply during appeal. Buyer
       appealed case Nos. 06 CH 3427 and 06 CH 3586, consolidated (appeal No. 1-12-0432),
       claiming that the trial court deprived Buyer of its statutory right to postjudgment interest. We
       subsequently consolidated the separate appeals.

                                                    - 12 -
¶ 41                                          II. ANALYSIS
¶ 42       There are two consolidated appeals before this court. First, Seller appeals the trial court’s
       judgment in favor of Buyer, claiming: (1) that the Hy-Vee Holdback is not a valid liquidated
       damages provision because it amounted to an unenforceable penalty; (2) that the trial court
       erred in finding the parties’ agreement ambiguous; (3) that the trial court’s interpretation of the
       parties’ contract violates Illinois rules of contract interpretation; and (4) that the trial court
       erred as a matter of law in failing to award attorney fees to Seller. In response, Buyer claims:
       (1) that the Hy-Vee Holdback is a valid and enforceable liquidated damages provision; (2) that
       the trial court’s finding that the contract terms were ambiguous and required extrinsic evidence
       to interpret the parties’ intent was reasonable; (3) that Seller forfeited several of its arguments
       concerning the trial court’s contract construction; and (4) that Seller is not entitled to attorney
       fees. Second, Buyer appeals the trial court’s order denying it postjudgment interest, claiming
       that the trial court deprived Buyer of its statutory right. For the following reasons, we reverse
       the trial court’s finding that the liquidated damages clause was enforceable because the clause:
       (1) failed to satisfy the Jameson factors, (2) resulted in a windfall for Buyer, and (3) functions
       as a penalty for Seller’s 91-day nonperformance.

¶ 43                                        A. Seller’s Appeal
¶ 44        Whether a contractual provision for damages is a valid liquidated damages provision or is
       an unenforceable penalty clause is a question of law that is reviewed de novo. Penske Truck
       Leasing Co. v. Chemetco, Inc., 311 Ill. App. 3d 447, 454 (2000). De novo consideration means
       we perform the same analysis that a trial judge would perform. Khan v. BDO Seidman, LLP,
       408 Ill. App. 3d 564, 578 (2011).
¶ 45        Buyer argues in its brief that the appropriate standard of review in determining the validity
       of the liquidated damages clause would be an abuse-of-discretion standard because the trial
       court made several findings of fact by concluding that the liquidated damages clause was
       enforceable. However, at the oral argument of the case, Buyer conceded that the appropriate
       standard of review in determining this issue would be de novo.
¶ 46        The central issue in Seller’s appeal is whether the Hy-Vee Holdback is a valid and
       enforceable liquidated damages provision. Seller claims that public policy dictates that the
       Hy-Vee Holdback provision is an unenforceable penalty because it confers a windfall award to
       the nonbreaching party, and it does not specify damages for a specific breach. Buyer responds
       that the provision is not a penalty because Illinois courts have previously upheld liquidated
       damages clauses for delayed performance, even when the nonbreaching party has suffered
       little or no actual damages. For the following reasons, we find that the Hy-Vee Holdback is an
       unenforceable liquidated damages provision.
¶ 47        When interpreting contract provisions that specify damages, Illinois courts draw a
       distinction between liquidated damages, which are enforceable, and penalties, which are not.
       Checkers Eight Ltd. Partnership v. Hawkins, 241 F.3d 558, 562 (7th Cir. 2001). “The test for
       determining whether a liquidated-damages clause is valid as such or is void as a penalty is
       stated in section 356 of the Restatement (Second) of Contracts: ‘Damages for breach by either
       party may be liquidated in the agreement but only at an amount that is reasonable in the light of
                                                    - 13 -
       the anticipated or actual loss caused by the breach and the difficulties of proof of loss. A term
       fixing unreasonably large liquidated damages is unenforceable on grounds of public policy as a
       penalty.’ ” Penske Truck Leasing Co., 311 Ill. App. 3d at 454 (quoting Restatement (Second)
       of Contracts § 356 (1979)). “It is a general rule of contract law that, for reasons of public
       policy, a liquidated damages clause that operates as a penalty for nonperformance or as a threat
       to secure performance will not be enforced.” Jameson Realty Group v. Kostiner, 351 Ill. App.
3d 416, 423 (2004) (citing Med+Plus Neck & Back Pain Center v. Noffsinger, 311 Ill. App. 3d
853, 860 (2000), and Grossinger Motorcorp, Inc. v. American National Bank & Trust Co., 240
Ill. App. 3d 737, 749 (1992)). In doubtful cases, we are inclined to construe the stipulated sum
       as a penalty. Stride v. 120 West Madison Building Corp., 132 Ill. App. 3d 601, 605 (1985)
       (citing Beuttas v. Garvey, 270 Ill. App. 310, 318 (1933)). Furthermore, “[t]he purpose of
       damages is to place the nonbreaching party in a position that he or she would have been in had
       the contract been performed, not to provide the nonbreaching party with a windfall recovery.”
       Jones v. Hryn Development, Inc., 334 Ill. App. 3d 413, 418 (2002).

¶ 48                                    1. The Jameson Factors
¶ 49       In Illinois, courts will generally find a liquidated damages provision to be valid and
       enforceable when the three factors laid out in Jameson are satisfied. As stated in Jameson, the
       three elements that must be met in order to validate a liquidated damages clause are: (1) the
       parties intended to agree in advance to the settlement of damages that might arise from the
       breach; (2) the amount of liquidated damages was reasonable at the time of contracting,
       bearing some relation to the damages which might be sustained, and (3) actual damages would
       be uncertain in amount and difficult to prove. Jameson, 351 Ill. App. 3d at 423. Of note, all
       three requirements must be met in order to enforce a liquidated damages clause. Here, the
       Hy-Vee Holdback does not meet the first two requirements of the Jameson requirements. As
       such, the clause is not a valid and enforceable liquidated damages clause.

¶ 50                            a. The Parties Did Not Agree in Advance
                             That the $4.3 Million Would Be Damages for a
                                       Delay in Obtaining Permits
¶ 51       The first factor of the Jameson test that must be met in order to validate a liquidated
       damages clause is that the parties intended to agree in advance to the settlement of damages
       that might arise from the breach. Jameson, 351 Ill. App. 3d at 423. Here, there is no evidence to
       suggest that the parties even considered what appropriate damages would be in the event of a
       minor delay in obtaining permits. Rather, the evidence shows that the parties considered the
       damages in light of a complete failure of the Hy-Vee Lease to come to fruition and,
       accordingly, estimated the damages as the present-day value of the entire 20-year lease, or the
       equivalent of $4.3 million. Because there is no evidence that the parties contemplated damages
       for a minor delay in obtaining permits at the time of creating the liquidated damages clause, we
       cannot say that the parties agreed in advance that $4.3 million would represent the damages for
       any breach, including a delay of 91 days in obtaining permits.

                                                  - 14 -
¶ 52        While we realize that the trial court found that the first prong of Jameson had been met, we
       find that the trial court improperly interpreted that prong. The trial court concluded that the
       first prong was met because “the insertion and amount of the liquidated damages clause was
       intentional and negotiated through an arm’s-length transaction.” While we don’t disagree with
       these facts as stated by the trial court, we find that such facts do not satisfy the first prong of
       Jameson, which requires a showing that the parties intended to agree in advance to the
       settlement of damages that might arise from the breach. Jameson, 351 Ill. App. 3d at 423. The
       mere negotiation and insertion of the liquidated damages clause does not show that the parties
       intended to agree in advance that $4.3 million would serve as liquidated damages for a 91-day
       delay (or any delay) in obtaining permits, while leaving the entire value of the 20-year lease
       still intact. Therefore, the Hy-Vee Holdback did not satisfy the first prong of the Jameson test
       and, as a result, it cannot be enforced as a valid liquidated damages provision.

¶ 53                           b. The Amount of Liquidated Damages Bore
                                  No Relation to the Anticipated Damages
                                         of a Delay in Performance
¶ 54       Even though failing to satisfy the first prong would be sufficient to find the Hy-Vee
       Holdback unenforceable, we find that the second prong was also not satisfied here. The second
       Jameson element that must be met in order to enforce a liquidated damages clause is that the
       amount of the liquidated damages was reasonable at the time of contracting, bearing some
       relation to the damages that might be sustained. Jameson, 351 Ill. App. 3d at 423. Here, the
       parties negotiated a $4.3 million holdback, which represented the entire, present-day value of
       the 20-year lease, in the event that the lease did not go through. In coming to this number, the
       parties calculated that Buyer would lose $430,000 each year in rent if the Hy-Vee Expansion
       lease did not go through. Thus, while the $4.3 million in liquidated damages might have been
       reasonable in the event that the Hy-Vee lease never occurred, it was not reasonable for a
       91-day delay in securing government permits. The holdback amount of $4.3 million simply
       does not bear any relation to the damages sustained for a 91-day delay in securing permits and,
       therefore, was not a reasonable prediction of damages. See Dallas v. Chicago Teachers Union,
       408 Ill. App. 3d 420, 425 (2011) (parties not required to make the best estimation of damages,
       but must make one that is reasonable).
¶ 55       In fact, Buyer concedes in two places that $4.3 million is not an estimate of damages for a
       91-day delay in obtaining permits. First, in coming to the $4.3 million figure, the parties agreed
       that the damages in yearly lost rent would be $430,000 per year. Thus, it cannot be said that a
       91-day delay, which makes up a small fraction of a year, could reasonably result in $4.3
       million of potential damages. Second, in its November 16 proposal, Buyer offered to extend
       the October 31, 2005 deadline in exchange for, among other things, paying the monthly rent it
       would lose as a result of the delay, which it estimated to be $47,000 per month plus a pro rata
       share of real estate taxes and CAM. Even if we multiply this monthly rate by three to equal the
       91-day delay, the total is nowhere near $4.3 million. Again, this shows that $4.3 million had no
       relation whatsoever to the damages that might result from a 91-day delay in obtaining permits.
       As such, it is clear that the $4.3 million was not a reasonable estimate of damage for a 91-day
                                                    - 15 -
       delay in obtaining permits and, accordingly, Buyer cannot establish the second prong of the
       Jameson test. Given that all three factors must be met in order to validate a liquidated damages
       clause, we find that the Hy-Vee Holdback was not a valid and enforceable liquidated damages
       provision.

¶ 56                2. The Hy-Vee Holdback Amounted to a Windfall Recovery for Buyer
¶ 57       Our courts have invalidated liquidated damages clauses where they amount to a windfall
       for one of the parties. Jones, 334 Ill. App. 3d at 418. Our courts have also invalidated
       liquidated damages clauses based on public policy concerns where the purpose of the clause is
       to punish nonperformance rather than estimate damages. Stride, 132 Ill. App. 3d at 605. In the
       case at bar, the Hy-Vee Holdback must be invalidated based on public policy concerns for both
       of these reasons because it amounts to a windfall for Buyer and a penalty for Seller’s 91-day
       “nonperformance” delay.
¶ 58       The Hy-Vee Holdback constitutes an unenforceable penalty clause because the provision
       amounted to a windfall recovery for Buyer. Here, the trial court awarded Buyer the entire $4.3
       million for only a 91-day delay in approving construction permits even though the entire 20 to
       45-year lease was still intact and Buyer would receive the benefits of that lease for the next 20
       to 45 years. The damages awarded from the Hy-Vee Holdback, $4.3 million, are grossly
       disproportionate to the loss Buyer could have sustained in the event of a delay in obtaining
       construction permits. In essence, the trial court has allowed Buyer to receive a double recovery
       by not paying the $4.3 million purchase price for the Hy-Vee lease while still recovering the
       $4.3 million for the Hy-Vee lease over the next 20 years plus.
¶ 59       The evidence at trial shows that the purpose of the Hy-Vee Holdback was to compensate
       Buyer for the full value that it would have lost in the event that the Hy-Vee Expansion did not
       take place. Buyer’s primary negotiator, Tom Rogers, testified that the Hy-Vee Holdback was a
       calculation of the present value of the Hy-Vee Expansion. To arrive at this figure, Rogers
       determined that the new Hy-Vee Lease would generate an incremental income of $430,000 per
       year. From there, Rogers calculated that the Hy-Vee Expansion’s capitalization rate would be
       10%, which is the percentage of the property’s cost that would be paid by the net proceeds
       from the Hy-Vee Lease. To determine the present value of the Hy-Vee Expansion, Rogers then
       divided the annual income by the capitalization rate. The final figure, $4.3 million, represented
       the value of the Hy-Vee Expansion in consideration of the Hy-Vee Lease. Buyer argues that
       this figure was just a middle ground estimate that calculated losses over a 10-year period, and
       points to the trial court’s finding that the parties arrived at an in-between valuation by
       calculating the annual income with a multiplier of 10. This, however, misunderstands the
       nature of a capitalization rate, which is commonly used to calculate the present value of
       commercial real estate. The evidence shows that the negotiations focused on using the
       capitalization to determine the purchase price of Hy-Vee Expansion, and not just merely
       multiplying the expected annual income by 10.
¶ 60       By contrast, Buyer’s actual damages from the breach are significantly less. Though neither
       party provides an exact figure of Buyer’s actual damages, the evidence at trial is instructive in
       arriving at a reasonable figure. Seller points to Buyer’s November 16 proposal in which Buyer
                                                    - 16 -
       contemplated extending the October 31, 2005 deadline in exchange for Seller paying Buyer for
       rent that it would have been paid had the permits been approved on time. The payments
       consisted of monthly payments of $47,000, plus a pro rata share of real estate taxes and CAM.
       Though Seller claims that this figure is inflated, it is far closer to the actual damages sustained
       in the event of a delay than the damages awarded by the Hy-Vee Holdback. Thus, Buyer was
       conferred a substantial windfall when it was awarded the full $4.3 million value of the Hy-Vee
       Holdback for a temporary delay that Buyer had attempted to settle for a significantly lesser
       amount. 3
¶ 61       Buyer claims that the damages were reasonable and not an excessive windfall because the
       magnitude of potential damages at the time of the contract was great. Buyer argues that, had
       the deadline not been met, the future of the Hy-Vee Expansion could have potentially been in
       jeopardy. If the Hy-Vee Expansion had not been completed, the Mall could have lost
       significant value, and the vacancy of a major anchor store could have hurt the Mall’s ability to
       attract future tenants, which would damage the Mall’s viability. However, there is scant
       evidence, if any, that the Hy-Vee Expansion was in danger of complete failure. A new Hy-Vee
       Lease had been signed, final plans and specifications had been approved, asbestos removal had
       been completed, and construction had begun on parking lot improvements. The appellate
       record does not show that either party had a significant obstacle that would endanger the
       completion of the Hy-Vee Expansion. In fact, the only delay in delivery of the premises was
       due to the approval of construction permits, which had been applied for before the deadline
       expired. As such, the Hy-Vee Expansion was completed in November 2006, at which point
       Hy-Vee began making rent payments under its new lease. Such a scenario was not
       unforeseeable when the parties executed the Deed and Money Escrow in 2004. The parties thus
       erred in negotiating a damages provision that conferred an unreasonably large recovery for a
       minor delay.
¶ 62       Further, there is nothing in the evidence to suggest that if the Hy-Vee lease did not go
       through, that the space formerly rented by Wal-Mart could not be rented to anyone else for
       twenty years. Thus, Buyer’s arguments about speculative and incredible potential damages do
       not change the fact that allowing Buyer to keep the $4.3 million and make an additional $4.3
       million over the next 20 years was an unreasonable windfall.
¶ 63       Penske Truck Leasing Co. is instructive here. In Penske Truck Leasing Co., the lessor of a
       vehicle lease agreement brought suit against the guarantor, and sought enforcement of the
       lease’s liquidated damages provision. Penske Truck Leasing Co., 311 Ill. App. 3d at 457-58.
       The liquidated damages clause in the agreement provided different methods of calculating
       damages for the nonbreaching lessor depending on whether it retained or sold the vehicles. Id.
       at 457. By calculating the damages before it sold the vehicles, the lessor was able to then sell
       the vehicles afterwards for a windfall. Id. Based on this, the appellate court found that the
       liquidated damages provision was unenforceable because the parties did not intend for the
       lessor to reap a windfall, and that “the award entered by the trial court [thereunder] was well in

           3
           Further, it appears that Buyer did not suffer any “lost” rent as the 20-plus-year lease was merely
       pushed back 91 days. Buyer will still receive the entire profit anticipated from the 20-year lease.
                                                    - 17 -
       excess of the actual damages suffered by [the lessor].” Id. The appellate court remanded the
       case to the trial court with instructions to calculate damages using a formula that more
       accurately reflected the lessor’s actual losses. Id. In the instant case, the damages provision
       similarly provided Buyer with a windfall recovery well in excess of the actual damages
       suffered.
¶ 64       Buyer argues that Penske Truck Leasing Co. is distinguishable because the appellate court
       ultimately enforced the liquidated damages provision, finding that “the agreement provided for
       an enforceable liquidated-damages provision and not an unenforceable penalty.” Id. at 455-56.
       Though the appellate court reversed in part and remanded the case back to the trial court, it did
       so because it found that the trial court applied the incorrect formula for determining the amount
       of damages to be awarded for the complained default. Id. at 457-58. Buyer’s argument
       mischaracterizes the central finding in the case. Penske Truck Leasing Co. states:
                   “In the instant case, *** paragraph 15 of the agreement provides alternative
               methods of computing damages. One method is applicable if plaintiff decides to sell
               the vehicles, while another method is used if plaintiff retains the vehicles. The trial
               court awarded damages based upon the method which assumed that plaintiff retained
               the vehicles. While Mr. Douglas testified that plaintiff initially decided to retain the
               vehicles because of a depressed market, the evidence is clear that plaintiff ultimately
               sold all four vehicles for $30,400 each. We are certain that it was never the intention of
               the parties to permit plaintiff to proceed under the method of recovery used when
               plaintiff decides to retain the vehicle but later sell the vehicles and reap a windfall in the
               process. If we allowed plaintiff to proceed in this manner, the damages would be so
               unreasonable that we should refuse to enforce the provisions of paragraph 15, and that
               paragraph would have to be considered a penalty provision.” Id. at 457.
       Thus, the appellate court found that the relevant provision upon which the parties calculated
       damages was unenforceable as a penalty because it conferred a windfall on the nonbreaching
       party far in excess of the actual damages that it sustained.
¶ 65       Buyer also claims that, though the amount of liquidated damages awarded to Buyer may
       have been greater than the amount of actual damages it sustained, Illinois courts have held that
       “[t]he nature of a liquidated damages provision is such that the set amount may at times exceed
       actual damages.” Karimi v. 401 North Wabash Venture, LLC, 2011 IL App (1st) 102670, ¶ 27.
       Buyer also points to comment b in section 356 of the Restatement (Second) of Contracts,
       which states that a fixed amount of liquidated damages is reasonable “to the extent that it
       approximates the [actual] loss anticipated at the time of the making of the contract, even
       though it may not approximate the actual loss.” Restatement (Second) of Contracts § 356
       cmt. b (1979). Buyer argues that at the time the parties executed the Third Amendment in
       2004, the Hy-Vee Holdback was a middle-ground estimate of what the potential damages may
       have been, and that the liquidated damages provision was enforceable even though the
       resulting damages from a breach could have been potentially higher or lower than the actual
       damages depending on any number of scenarios that may have unfolded.
¶ 66       Although liquidated damages may at times exceed the amount of actual damages, a
       damages clause providing “ ‘unreasonably large liquidated damages is unenforceable on
                                                     - 18 -
       grounds of public policy as a penalty.’ ” Penske Truck Leasing Co., 311 Ill. App. 3d at 454
       (quoting Restatement (Second) of Contracts § 356 (1979)). As stated above, the damages
       awarded by the Hy-Vee Holdback for a delay in permit approval were unreasonably large
       because they far exceeded the amount of actual damages that Buyer sustained, thus resulting in
       a windfall to Buyer.

¶ 67                              3. The Purpose of the Hy-Vee Holdback
                           Was to Secure Performance/Punish Nonperformance
¶ 68        We also find that the Hy-Vee Holdback was intended to secure performance and to punish
       nonperformance. It is a general rule of contract law that, for reasons of public policy, a
       liquidated damages clause which operates as a penalty for nonperformance will not be
       enforced. Jameson, 351 Ill. App. 3d at 422; Stride, 132 Ill. App. 3d at 605 (“if the clause fixing
       damages is merely to secure performance of the agreement, it will be treated as a penalty and
       only actual damages proved can be recovered”). Given that the Hy-Vee Holdback of $4.3
       million has no reasonable relation to damages caused by a 91-day delay in obtaining permits,
       the clause was not intended to measure damages in the event of a delay, but rather intended to
       be a punishment in the event of a delay.
¶ 69        In Telenois, Inc. v. Village of Schaumburg, 256 Ill. App. 3d 897 (1993), a cable television
       franchise, Telenois, entered into a franchise agreement with the Village of Schaumburg
       whereby Telenois would provide cable services to the Village’s residents. Within the franchise
       agreement, there was a clause that stated: “ ‘This system reconfiguration will be completed by
       December 13, 1988. Franchisee will provide the Village with an unconditional Letter of Credit
       in the amount of One Hundred Thousand Dollars ($100,000) to be payable to the Village. In
       the event the Franchisee fails to complete this reconfiguration by December 31, 1988, the
       Village will collect the amount as a penalty.’ ” (Emphasis omitted.) Id. at 899. Telenois
       completed 99% of the reconfiguration by January 1989. The reason for the delay was due to the
       fact that Telenois could not complete the conversion without gaining access to some of the
       subscriber’s homes. Despite the fact that the configuration was 99% complete and the reason
       for the delay was not within Telenois’ control, the village collected the entire $100,000. The
       trial court ruled that the clause amounted to an unenforceable penalty clause against public
       policy, and on appeal, the appellate court agreed.
¶ 70        Like the contract clause in Telenois, the Hy-Vee Holdback clause states that Buyer would
       keep the $4.3 million if all the conditions were not met by a certain date, regardless of whether
       the conditions were never met at all or met after a slight delay. Further, like the delay that
       resulted in Telenois, which Telenois had no control over, here the 91-day delay that resulted
       was not within the control of Seller, as Hy-Vee was responsible for obtaining the necessary
       permits. While the appellate court in Telenois noted that the village’s witness acknowledged
       the clause in that contract to be a “penalty,” here, by conceding in the November 16 proposal
       that delay damages per month would be drastically less that the entire $4.3 million Hy-Vee
       Holdback, Buyer has impliedly conceded that the $4.3 million does not reflect damages for a
       91-day delay. Thus, because both the clause at issue here and the clause that was struck down
       in Telenois operate in the same manner and have the same all-or-nothing effect, the $4.3
                                                    - 19 -
       million Hy-Vee Holdback clause was not meant to measure damages resulting from a slight
       delay in performance and must not be enforced. 4
¶ 71       Buyer argues, though, that Illinois courts have recognized the validity of a liquidated
       damages clause in cases where a party’s performance is delayed, even when the nonbreaching
       party has not suffered any actual damages. In making this argument, Buyer relies on Bethlehem
       Steel Corp. v. City of Chicago, 350 F.2d 649 (7th Cir. 1965), which is the same case the trial
       court relied on in concluding that the liquidated damages clause here was enforceable. In
       Bethlehem Steel, Bethlehem contracted to sell steel to the City of Chicago as a part of the Dan
       Ryan Expressway construction project, which the city wanted to have completed by a certain
       date. Bethlehem Steel, 350 F.2d at 650-51. The contract provided that Bethlehem would deliver
       steel by the deadline or it would be liable for liquidated damages. Id. at 651. Though
       Bethlehem delivered the steel 52 days late, the construction was completed on schedule. Id.
       Bethlehem argued that the City of Chicago was not entitled to liquidated damages because it
       had not incurred any harm or actual damages. Id. The Seventh Circuit rejected Bethlehem’s
       argument, finding that “Bethlehem now seeks to re-write the contract and to relieve itself from
       the stipulated delivery dates for the purposes of liquidated damages, and to substitute therefor
       the City’s target date for the scheduled opening of [its] super highway. This [Bethlehem]
       cannot do.” Id. In finding a valid liquidated damages clause, the Seventh Circuit relied on Wise
       v. United States, 249 U.S. 361 (1919), which found that courts “ ‘look with candor, if not with
       favor, upon such provisions in contracts when deliberately entered into between parties who
       have equality of opportunity for understanding and insisting upon their rights, as promoting
       prompt performance of contracts and because adjusting in advance, and amicably, matters the
       settlement of which through courts would often involve difficulty, uncertainty, delay and
       expense.’ ” Bethlehem Steel, 350 F.2d at 651 (quoting Wise, 249 U.S. at 366).
¶ 72       However, Bethlehem is distinguishable from the instant case because the liquidated
       damages clause there provided a specific calculation for delay as a linear function of time at a
       rate of $1,000 per day. Bethlehem Steel, 350 F.2d at 650. In doing so, the damages clause
       provided a reasonable amount of damages for delayed performance because each day of delay
       affected the other parties’ ability to perform, which justified the amount of damages. Id. at 651.
¶ 73       In the case at bar, the Hy-Vee Holdback does not distinguish between minor delays in
       performance and a complete failure of the Hy-Vee Expansion, and there is certainly no per-day
       damage rate that was contemplated by the parties. “The element common to most liquidated
       damages clauses that get struck down as penalty clauses is that they specify the same damages
       regardless of the severity of the breach.” XCO International Inc. v. Pacific Scientific Co., 369
F.3d 998, 1004 (7th Cir. 2004) (citing Checkers Eight Ltd. Partnership, 241 F.3d at 562, Lake
       River Corp. v. Carborundum Co., 769 F.2d 1284, 1290 (7th Cir. 1985), M.I.G. Investments,
       Inc. v. Marsala, 92 Ill. App. 3d 400 (1981), and Kalenka v. Taylor, 896 P.2d 222, 228-29

           4
            Further, as noted by the Seventh Circuit, Illinois courts continue to invalidate liquidated damage
       clauses even where both parties are economically sophisticated. Checkers Eight Ltd. Partnership, 241
F.3d at 563 (citing Telenois, 256 Ill. App. 3d 897); Grossinger Motorcorp, Inc., 240 Ill. App. 3d 737.
       Thus, any argument that the parties were sophisticated in the case should hold little to no weight.
                                                     - 20 -
       (Alaska 1995)). “[T]he damages contained in a liquidated damages clause must be for a
       specific amount for a specific breach; the provision may not merely serve as a threat to secure
       performance or as a means to punish nonperformance.” Jameson, 351 Ill. App. 3d at 424
       (citing Noffsinger, 311 Ill. App. 3d at 860); see also Builder’s Concrete Co. of Morton v. Fred
       Faubel & Sons, Inc., 58 Ill. App. 3d 100, 107 (1978) (A liquidated damages clause “must be a
       specified amount for a specific breach to be paid as an alternative to performance and not as a
       penalty for nonperformance.”).
¶ 74        It is undisputed that the Hy-Vee Holdback provided the same amount of damages
       regardless of the type or extent of the breach. “When a contract specifies a single sum in
       damages for any and all breaches even though it is apparent that all are not of the same gravity,
       the specification is not a reasonable effort to estimate damages; and when in addition the fixed
       sum greatly exceeds the actual damages likely to be inflicted by a minor breach, its character as
       a penalty becomes unmistakable.” Lake River Corp., 769 F.2d at 1290; see also Checkers Eight
       Ltd. Partnership, 241 F.3d at 562 (“If the amount of damages is invariant to the gravity of the
       breach, the clause is probably not a reasonable attempt to estimate actual damages and thus is
       likely a penalty.”).
¶ 75        For the foregoing reasons, the Hy-Vee Holdback is unenforceable as it functions as a
       penalty where it fails to distinguish between a minor delay in permit approval and a complete
       failure of the construction project. As such, the Hy-Vee Holdback sought to award the entire
       value of the Hy-Vee Expansion for a temporary delay, which constitutes an unenforceable
       penalty to coerce performance rather than a valid liquidated damages provision.
¶ 76        In sum, because the Hy-Vee Holdback (1) does not meet the three requirements necessary
       under Jameson to validate a liquidated damages clause, (2) results in a windfall to Buyer, and
       (3) functions as a penalty for nonperformance, we find it to be invalid and unenforceable.
       Because Buyer is entitled to any actual damages it suffered as a result of the 91-day delay, we
       remand this cause to the trial court to afford Buyer an opportunity to prove its actual damages.
       See Grossinger Motorcorp, Inc., 240 Ill. App. 3d at 752 (after liquidated damages clause is
       held to be unenforceable, defendant is entitled to actual damages, if any can be proven).
¶ 77        Seller also claims that the trial court erred in finding that the Deed and Money Escrow was
       ambiguous, and that the trial court violated several principles of contract interpretation when
       construing the terms of the parties’ agreement. Since we find that the Hy-Vee Holdback is an
       unenforceable penalty, we need not address these contentions.

¶ 78                                        B. Attorney Fees
¶ 79       Seller argues that the trial court erred as a matter of law in failing to award it attorney fees
       under the Reaffirmation Agreement executed by Buyer prior to closing on December 14, 2004.
       Under the agreement, Buyer promised to “indemnify and hold harmless Sellers and each of
       them from and against any and all loss, cost, debt, damage (including court costs and
       reasonable attorney fees) for liability arising out of, directly or indirectly, the failure of any
       Assignee to perform the Undertakings pursuant to its assignment or arising out of its need to
       enforce the terms of this Reaffirmation, or both.” However, the parties agree that an award of
       attorney fees under the Reaffirmation Agreement is contingent on the existence of a breach by
                                                     - 21 -
       Buyer. We remand to the trial court to decide the issue of breach by Buyer, which could
       include reasonable court costs and attorney fees.

¶ 80                                     C. Buyer’s Appeal
¶ 81      With regard to Buyer’s appeal, Buyer claims that the trial court’s order denying
       postjudgment interest was in error because it deprived Buyer of its statutory right. However,
       we need not consider this issue since there is no money award.

¶ 82                                        III. Conclusion
¶ 83       For the foregoing reasons, the trial court’s order awarding the $4.3 million held in escrow
       to Buyer is reversed. Upon remand, the trial court is directed to afford buyer an opportunity to
       prove actual damages it suffered as a result of the 91-day delay, deduct such damages from the
       escrow to be awarded to Buyer, and order the release of the remaining funds to Seller. Seller’s
       claim concerning attorney fees is also remanded to the trial court with instructions to decide the
       issue of breach by Buyer, including the issue of attorney fees and costs.
¶ 84       In light of the ruling that Buyer is not entitled to the $4.3 million holdback we need not
       consider the issue of whether Buyer is entitled to postjudgment interest.

¶ 85      Affirmed in part and reversed in part with instructions.

                                                   - 22 -