Court Opinion

ID: 75987
Source: CourtListenerOpinion
Date Created: 2010-04-26 23:48:18+00
Date Added: 2024-06-11T15:01:43.520475
License: Public Domain

[PUBLISH]

           IN THE UNITED STATES COURT OF APPEALS

                  FOR THE ELEVENTH CIRCUIT
                                                         FILED
                                               U.S. COURT OF APPEALS
                                                 ELEVENTH CIRCUIT
                          No. 01-11864             September 13, 2002
                                                  THOMAS K. KAHN
                D.C. Docket Nos. 99-01992CV-AR-S        CLERK
                      and 99-013149 CV-AR-S

UNIVERSITY COMMONS-URBANA, LTD.,
CAPSTONE DEVELOPMENT CORP.,

                                                    Plaintiffs-Counter-
                                                 Defendants-Appellees,

                        versus

UNIVERSAL CONSTRUCTORS INC.,
RELIANCE INSURANCE COMPANY,

                                                  Defendants-Counter-
                                                 Claimants-Appellants.

UNIVERSAL CONSTRUCTORS INC.
RELIANCE INSURANCE COMPANY,

                                                  Plaintiffs-Appellants,

                        versus

UNIVERSITY COMMONS-URBANA
CAPSTONE DEVELOPMENT CORP., its General
Partner,

                                                 Defendants-Appellees.
                      Appeal from the United States District Court
                         for the Northern District of Alabama

                                  (September 13, 2002)

Before TJOFLAT and BIRCH, Circuit Judges, and GOLDBERG*, Judge

TJOFLAT, Circuit Judge.

         In this appeal, Universal Constructors, Inc. (“Universal”) and Reliance

Insurance Company (“Reliance”) challenge a district court order confirming an

arbitration award entered in favor of University Commons-Urbana, Ltd.

(“University Commons”) and Capstone Development Corporation (“Capstone

Development”). One of the grounds of appellants’ challenge is that a member of

the arbitration panel was not impartial. The district court rejected this ground on

its face, without holding an evidentiary hearing. We conclude that appellants’

allegations of partiality are sufficient to warrant an evidentiary hearing. We

therefore vacate the award and remand the case so that an evidentiary hearing may

be held and findings of fact and conclusions of law may be made concerning the

issue.

_________________________________________________
*Honorable Richard W. Goldberg, U.S. Court of International Trade Judge, sitting by
designation.

                                              2
                                          I.

      University Commons is an Illinois-based limited partnership formed by

Capstone Development, a Birmingham-based developer that specializes in student-

oriented apartment projects for colleges and universities throughout the United

States. Some of Capstone’s projects are developed “on campus” in conjunction

with colleges and universities, while others are developed “off campus” through a

limited partnership. University Commons was just such a partnership, formed to

develop an off-campus apartment project (the “Project”) near the University of

Illinois, in Urbana.

      In September 1997, University Commons contracted with Universal to build

these apartments. Specifically, the contract called for Universal to erect 132 four-

bedroom and 108 two-bedroom student apartment units, a club house, a swimming

pool, a maintenance building, and a duplex. Reliance acted as Universal’s surety

and issued a $13,218,664 performance bond guaranteeing Universal’s performance

of the Project.

      The Project was scheduled for completion in August 1998. Universal did

not meet this deadline, however. On April 1, 1999, with the pool unfinished and

landscaping work still to be done, Capstone Development sent Universal a notice

terminating their contract on the ground that Universal’s failure to complete the job

                                          3
on time constituted a material breach. Later that month, Capstone Development

hired Capstone Building Corporation (“Capstone Building”) to complete the job.

Capstone Building completed the project by July 31, 1999.

      On June 14, 1999, University Commons filed a Demand for Arbitration with

the American Arbitration Association (“AAA”), alleging breach of contract against

Universal. University Commons sought $3,649,669.98 in damages from Reliance

under the Performance Bond, including $286,899 for deductive change orders,

$555,285.34 for the cost of repairing, replacing, or completing Universal’s work,

and $3,307,485.64 for the damage allegedly caused by Universal’s failure to

complete the project on schedule. The bulk of this $3,307,485.64 that Universal

sought as compensation for the delay was lost rental income, specifically

$1,099,464 for the 1998-1999 school year and $1,989,700 for the 1999-2000

school year.

      University Commons and Capstone Development presented these same

claims and sought these same damages in a law suit they brought in the United

States District Court for the Northern District of Alabama on July 30, 1999. The

court stayed prosecution of the case on December 7, 1999, after the parties

mutually consented to submit the case to arbitration.

      In August 1999, the AAA provided the parties with a list of fifteen possible

                                         4
arbitrators and their resumes. Each party had the right to strike five of the

arbitrators on a peremptory basis and rank the remaining names on the list in order

of preference. The AAA would then fashion a tribunal based on the parties’

preferences. In the arbitration in this case, styled University Commons-Urbana,

Ltd. c/o Capstone Development Corp. and Universal Constructors, Inc., and

Reliance Insurance Company, the AAA ultimately named a panel comprised of

three arbitrators, including Edward P. Meyerson, an experienced construction

attorney.

      The arbitration itself ran from April to June 2000 and was conducted in three

parts. During the first set of hearings, from April 17 to April 25, 2000, University

Commons set forth its case-in-chief. Then, from June 1 until June 8, 2000, the

hearings continued into a second session as Universal and Reliance presented their

case-in chief. Finally, the hearings resumed for a third time from July 10 to July

12, 2000, for the parties’ rebuttals and closing arguments.

       Prior to the arbitration hearings, the parties held several telephone

conference calls with the arbitrators to discuss scheduling and the depositions that

needed to be taken. During none of these calls, the first of which occurred on

November 11, 1999, did Meyerson disclose any involvement with the parties, their

witnesses, or their counsel – Bradley Arant Rose & White LLP (“Bradley Arant”),

                                          5
counsel for University Commons, and Smith, Currie & Hancock LLP, counsel for

Universal. In fact, Meyerson never made any written disclosure of any kind

indicating that he had a financial or personal interest which might affect his

partiality.

        At the start of the arbitration hearings on April 17, 2000, Meyerson

indicated, however, that he knew and had worked with and against the attorneys

and law firms who represented both sides in the arbitration. This would not be

Meyerson’s last disclosure: During the course of the arbitration hearings, he also

would reveal other previous contacts with people who had interests in the

arbitration. For instance, at some point during the arbitration process, Meyerson

informed the parties that he had met with a representative from Capstone Building

to discuss possible legal representation.1 In addition, at the end of the hearings,

when Jeff Schattinger, Capstone Development’s construction manager, appeared to

testify, Meyerson acknowledged that he had met Schattinger previously. Despite

these disclosures, there is no evidence in the record that Universal or Reliance

objected to Meyerson’s role as an arbitrator during any stage of the arbitration

       1
         The parties contest when Meyerson made this disclosure: Meyerson and
University Commons insist that Meyerson revealed his contact with Capstone
Building at the initial arbitration hearing; whereas, Ronald Robey, an attorney for
Universal, insists that Meyerson made no mention of it until the second series of
arbitration hearings.
                                          6
hearings.

      On August 17, 2000, the arbitrators rendered their decision, awarding

$2,248,648 to University Commons along with 12% interest per annum accruing

from August 15, 2000. Universal and Reliance received nothing on their

counterclaims. The arbitrators did not otherwise itemize the award of damages,

though. Consequently, they gave no indication as to what portions of the

$3,649,669.98, which University Commons originally sought in damages, they

thought had merit.

      Little time passed, however, before the award was challenged. On August

30, 2000, Universal and Reliance filed a petition to vacate the award in the United

States District Court for the Northern District of Georgia. University Commons

countered and filed a motion to confirm the award in the still pending litigation

(which had been stayed) in the Northern District of Alabama. On October 23,

2000, the district court in Georgia issued an order sua sponte transferring its case to

the Northern District of Alabama, and the district court there consolidated the two

cases the following month.

      On December 15, 2000, the parties met in accordance with Rule 26(f) of the

                                          7
Federal Rules of Civil Procedure,2 and the district court ordered them to proceed

with limited discovery, to be completed by March 5, 2001. On January 9, 2001,

Universal served University Commons with a set of discovery materials, including

a First Request for Admissions, First Interrogatories, and a First Request for

Production of Documents.3 Arguing that “the Federal Arbitration Act does not

      2
         Rule 26(f) provides:
Except in categories of proceedings exempted from initial disclosure under Rule
26(a)(1)(E) or when otherwise ordered, the parties must, as soon as practicable and
in any event at least 21 days before a scheduling conference is held or a scheduling
order is due under Rule 16(b), confer to consider the nature and basis of their
claims and defenses and the possibilities for a prompt settlement or resolution of
the case, to make or arrange for the disclosures required by Rule 26(a)(1), and to
develop a proposed discovery plan that indicates the parties' views and proposals
concerning:
          (1) what changes should be made in the timing, form, or
       requirement for disclosures under Rule 26(a), including a statement as
       to when disclosures under Rule 26(a)(1) were made or will be made;
          (2) the subjects on which discovery may be needed, when discovery
       should be completed, and whether discovery should be conducted in
       phases or be limited to or focused upon particular issues;
          (3) what changes should be made in the limitations on discovery
       imposed under these rules or by local rule, and what other limitations
       should be imposed; and
          (4) any other orders that should be entered by the court under Rule
       26(c) or under Rule 16(b) and (c).
Fed. R. Civ. P. 26(f).
      3
        Universal actually served University Commons with a nearly identical set
of discovery materials on December 28, 2000, but soon thereafter discovered
technical irregularities with one of its requests. Therefore, it resubmitted the
materials, corrected, to University Commons on January 9.
                                          8
authorize initial disclosures or discovery in connection with a Motion to Confirm

or Vacate an arbitration award,” University Commons objected to Universal’s

requests, but nonetheless purported to respond to them on February 7, 2001.

      In this February 7 response to Universal’s discovery requests, however,

University Commons refused to respond to most of Universal’s interrogatories and

declined most of Universal’s requests for admissions and documents. To illustrate,

of the twelve admissions Universal requested, University Commons denied

possessing the knowledge to answer eleven of them – all of which dealt with

whether Meyerson took part in various litigation in which Bradley Arant served as

counsel. Similarly, University Commons objected to fifteen of the eighteen

interrogatories that Universal submitted, because they sought information on

interactions between Meyerson and Bradley Arant and, according to University

Commons, “[Bradley Arant] is not a party and has no obligation to respond.”

Furthermore, with regard to two of the other three interrogatories, which sought

information regarding Meyerson’s previous dealings with Capstone Building and

Schattinger, University Commons professed to know no more than what was

previously revealed at the arbitration hearings.4 Not surprisingly, all of Universal’s

      4
       The one interrogatory that involved information clearly within University
Commons’ direct possession asked University Commons to “[i]dentify all
business, professional, civic, social, or other relationships and contacts during the
                                           9
requests for documents, which sought materials relevant to each of the

interrogatories, were refused by University Commons.

      Unhappy with University Commons’ response to its discovery requests,

Universal moved the court to compel discovery pursuant to Rule 37(a) of the

Federal Rules of Civil Procedure. At a hearing on the motion, the court, on its own

initiative, chose to revisit whether discovery should have been allowed at all. It

decided that its initial decision to allow discovery was incorrect and that it should

confirm the arbitration award without further debate.5 Therefore, the court, on

relevant time period between Edward P. Meyerson and University Commons.” In
response, University Commons said that it was “not aware of any such
relationships or contacts other than Mr. Meyerson’s service as an arbitrator [in this
case].”
      5
          The court’s reasons for changing its opinion are a bit muddled, but seem to
be motivated, at least in part, by a desire that this court confront the issue:
        And so forcing me, when this was presented, to go back to look at
        what the situation is, I think that while it’s an intriguing thing, it was
        to start with, with me, I think it’s the kind of thing that if you want to
        pursue it, it ought to be pursued now and with the Eleventh Circuit.
        There’s no point in my trying this case all over again one way or
        another and then having one of you go to the Eleventh Circuit, when
        you can go now and the way and the avenue and the vehicle to go is
        for me to agree with the arbitration award and let you all get the
        Eleventh Circuit to tell me, if they want to, that I’m wrong. And it
        won’t be the first time I’ve been told that, and it won’t hurt my
        feelings. So the plaintiffs in my court won’t hurt my feelings by
        getting me reversed.
Consequently, the court allowed the parties one week, from February 28 to March
1, to file further materials in the record before it issued a dispositive order.
                                          10
March 8, 2001, entered a final judgment confirming the arbitration award.

Universal and Reliance now appeal.

                                          II.

      Universal and Reliance have posited two separate reasons for us to overturn

the district court’s decision confirming the arbitration award. First, they claim that

the arbitrators, by awarding lost rental income for the 1999-2000 school year even

though the project was completed before this time period began, acted in “manifest

disregard for the law.” Second, Universal and Reliance assert that Meyerson’s

previous contacts with Bradley Arant, Capstone Building, and Schattinger

demonstrate enough prima facie evidence of Meyerson’s evident partiality that the

district court should have allowed discovery to continue. We consider the district

court’s rulings as to both of these arguments using a mixed standard: We review

district court’s factual findings for clear error and its legal conclusions de novo.

Gianelli Money Purchase Plan and Trust v. ADM Investor Servs., 146 F.3d 1309,

1310-11 (11th Cir. 1998) (discussing the standard of review for orders confirming

and negating arbitration awards).

                                          A.

      In Montes v. Shearson Lehman Bros., Inc., 128 F.3d 1456 (11th Cir. 1997),

we joined other circuits in holding that an arbitration decision could be vacated if

                                          11
the arbitrators, in making their decision, acted in “manifest disregard of the law.”

In reaching our conclusion, however, we emphasized that only “a manifest

disregard for the law, in contrast to a misinterpretation, misstatement or

misapplication of the law, can constitute grounds to vacate an arbitration decision.”

Id. at 1461-62. In other words, “[t]o manifestly disregard the law, one must be

conscious of the law and deliberately ignore it.” Brown v. ITT Consumer Fin.

Corp., 211 F.3d 1217, 1223 (11th Cir. 2000) (quoting Montes, 128 F.3d at 1461).

Consequently, “there must be some showing in the record, other than the result

obtained, that the arbitrators knew the law and expressly disregarded it.” O.R.

Sec., Inc. v. Prof’l Planning Assocs., Inc., 857 F.2d 742, 747 (11th Cir. 1988).

      Unfortunately, in the instant case, we have no showing in the record of the

arbitrator’s thoughts – other than the result. Universal and Reliance contend that

the arbitrators acted in manifest disregard for the law by awarding damages that

included lost rent for the 1999-2000 school year because the Project was completed

before the school year even began. But we cannot ascertain from the bare-bones

statement of the award what principle of law the arbitrators purportedly chose to

ignore when they awarded this rent.6 The statement simply lists the amounts

      6
         We cannot even tell for certain from the wording of the award whether the
arbitrators awarded the lost rent at all. The award simply says that Universal and
Reliance should pay $2,248,648 to University Commons, but does not indicate
                                          12
awarded to each party and is devoid of any mention of cases or treatises that might

have provided the underpinnings for the arbitrators’ decision. Furthermore, since

the hearings were not transcribed, we cannot even look at questions or offhand

remarks by the arbitrators for possible evidence of their legal rationale. In sum, we

have no indication of the arbitrators’ reasons for awarding the lost rent, and, thus,

we have no reason to believe that they disregarded the law in doing it. See id. (“In

fact, when the arbitrators do not give their reasons, it is nearly impossible for the

court to determine whether they acted in disregard of the law.”)

      This logic seems especially apt in a situation like the one before us, where

there does not appear to be any clear rule of law that the arbitrators might have

transgressed. There is, at least, some case law suggesting that delay damages can

be awarded for intervals after the completion of a construction project, if “the

residual effects of non-performance of the contract are carried over into a period

when the building is operational.” See Perini Corp. v. Greate Bay Hotel & Casino,

why that sum was chosen. Since University Commons sought $3,649,669.98 –
$1,989,700 of which was for lost rent for the 1999-2000 school year – one might
assume that an award greater than $1,659,969.98 – the difference between the total
sum sought and the figure for lost rent – would include some measure of damages
for that rent. This assumption only holds true, however, if the arbitrators, in their
calculation of the award, did not deviate from the accounting prepared by
University Commons. There is no way to determine whether the arbitrators made
such a deviation when they computed damages.
                                          13
Inc., 610 A.2d 364, 379 (N.J. 1992) (upholding an arbitration award that awarded

delay damages to a casino for its fall revenue after its renovation was substantially

complete in the summer because, among other reasons, “the possibility that the

public perception of the [casino] during the critical summer months could have had

a significant impact on [its] operations in the fall”), abrogated on other grounds by

Tretina Printing, Inc. Fitzpatrick & Assocs., Inc., 640 A.2d 788 (N.J. 1994)

(adopting narrower grounds on which arbitration awards may be vacated). While

we do not necessarily concur with this view, we would be hard-pressed to say,

without evidence of the arbitrators’ thinking, that they consciously ignored the law

in deciding the matter at hand.7

      Ultimately, due to both the paucity of the record and the unsettled nature of

the law on delay damages, we cannot find proof that the arbitrators recognized a

clear rule of law and, furthermore, chose to ignore it. Therefore, we cannot find

that the arbitrators acted in manifest disregard for the law by awarding damages

that included lost rent for the 1999-2000 school year.

      7
        Theoretically, we suppose, the arbitrators’ approach to the award of
damages could be in disregard of the law altogether, if it differed from the
provisions of the contract. Unfortunately for the appellants, while the case law on
contract interpretation is well-developed, we have no way to determine if the
arbitrators acted in knowing disregard of this case law because the contract was not
entered into the record.
                                          14
                                          B.

      Section 10 of the Federal Arbitration Act provides that a federal district

court may vacate an arbitration award “[w]here there was evident partiality or

corruption in the arbitrators . . . .” 9 U.S.C. § 10(a)(2). This rule is meant to be

applied stringently. As the Supreme Court emphasized in the seminal case of

Commonwealth Coatings Corp. v. Cont’l Cas. Co., 393 U.S. 145, 89 S. Ct. 337, 21

L. Ed. 2d 301 (1969), courts “should, if anything, be even more scrupulous to

safeguard the impartiality of arbitrators than judges, since the former have

completely free rein to decide the law as well as the facts and are not subject to

appellate review.” Id. at 149, 89 S. Ct. at 339.

      To maintain this sense of impartiality, the law imposes “the simple

requirement that arbitrators disclose to the parties any dealing that might create an

impression of possible bias.” Id. The key word in this rule is “impression.”

“Whether the arbitrator’s decision itself is faulty is not necessarily relevant.”

Woods v. Saturn Distrib. Corp., 78 F.3d 424, 427 (9th Cir. 1996). Disclosure

ensures that parties can view arbitration as a substitute for litigation, even though

the former is not bound by the same strictures of procedure and formality as the

latter. This practice, correspondingly, has been adopted by the various bodies that

oversee arbitrations. For example, under Rule 19 of the version of the AAA’s

                                           15
Construction Industry Arbitration Rules which were in effect at the time of this

case,8 “[a]ny person appointed as neutral arbitrator shall disclose to the AAA any

circumstance likely to affect impartiality, including any bias or any financial or

personal interest in the result of the arbitration or any part or present relationship

with the parties or their representatives.” Meyerson, therefore, had a duty to

disclose any potential conflicts he had to all of the parties.

      Universal and Reliance contend that he failed this obligation by providing

insufficient disclosures on three separate areas: (1) his previous legal interactions

with the Bradley Arant law firm in various mediations, arbitrations, and litigations;

(2) his interview with Capstone Building; and (3) his acquaintanceship with Jeff

Schattinger. We consider each in turn, keeping in mind the standard we have

established in this Circuit through our earlier cases. That is, “an arbitration award

may be vacated due to the ‘evident partiality’ of an arbitrator only when either (1)

an actual conflict exists, or (2) the arbitrator knows of, but fails to disclose,

information which would lead a reasonable person to believe that a potential

conflict exists.” Gianelli Money Purchase Plan & Trust v. ADM Investor Servs.,

      8
        Revised on July 1, 2001, the current version of the Construction Industry
Arbitration Rules, now called the Construction Industry Dispute Resolution
Procedures because they incorporates rule for both mediation and arbitration, still
contains this language verbatim, but as Rule 20.
                                           16
Inc., 146 F.3d 1309, 1312 (11th Cir 1998) (citing Lifecare Int’l, Inc. v. CD Med.,

Inc., 68 F.3d 429, 433 (11th Cir. 1995) and Middlesex Mut. Ins. Co. v. Levine, 675

F.2d 1197, 1202 (11th Cir. 1982)).

                                           1.

      It is undisputed that, at the onset of the initial set of arbitration hearings in

this case, Meyerson disclosed that he knew and had worked with the law firms

representing both parties in this arbitration. It is also undisputed that neither party

objected to Meyerson continuing as an arbitrator at that time. What Universal and

Reliance now contend is that Meyerson’s disclosure was inadequate and possibly

misleading – and thus, their own failure to object did not constitute waiver –

because Meyerson did not reveal the allegedly extensive nature of his relationship

with Bradley Arant. To determine whether Meyerson’s disclosure was sufficient,

we logically must conduct a two-step analysis: first, we must determine what

Meyerson needed to disclose; then, we must consider what he did disclose.

      As we have noted in our previous cases, an arbitrator is obligated to disclose

those facts that “create a reasonable impression of partiality,” Lifecare Int’l, 68

F.3d at 433 (citation omitted), or put another way, “information which would lead

a reasonable person to believe that a potential conflict exists.” Gianelli Money

Purchase Plan & Trust, 146 F.3d at 1312. The partiality alleged must be “direct,

                                           17
definite and capable of demonstration rather than remote, uncertain and

speculative.” Levine, 675 F.2d at 1202 (citation omitted). Here, the purported

partiality about which Universal and Reliance complain arises out of several

arbitrations, mediations, and litigations in which Meyerson and Bradley Arant both

took part. In examining these legal interactions, we may need to use different

standards, however, depending on when they occurred – that is, whether they

occurred prior to or concurrent with the arbitration between the parties in this case.

      To illustrate, we first consider those occasions on which Meyerson and

Bradley Arant participated in the same arbitrations, mediations, and litigations

prior to the arbitration in this case. At first blush, a large number of such

encounters would seem to imply an inappropriately close association between

arbitrator and counsel. Closer inspection reveals, however, that frequent

interactions between Meyerson and Bradley Arant may simply be the result of the

fact that both specialize in construction law in Birmingham, Alabama. Such

familiarity due to confluent areas of expertise does not indicate bias. Rather, so

long as the previous interactions do not represent part of an ongoing business

relationship, it may be an asset, since “an arbitrator’s experience in an industry, far

from requiring a finding of partiality, is one of the factors that can make arbitration

a superior means of resolving disputes.” Scott v. Prudential Sec., Inc., 141 F.3d

                                          18
1007, 1016 (11th Cir. 1998) (citing Commonwealth Coatings Corp., 393 U.S. at

150, 89 S. Ct. at 340 (White, J., concurring) (“It is often because they are men of

affairs, not apart from but of the marketplace, that they are effective in their

adjudicatory function.”)). Therefore, standing alone, the fact that an arbitrator, like

Meyerson, had previous contacts with counsel for one of the parties does not

suggest evident partiality.

      On the other hand, a reasonable person might envision a potential conflict if

an arbitrator, concurrently with the arbitration, partakes in a proceeding in which

counsel for one of the parties to the arbitration is also participating. Compare

Continental Ins. Co. v. Williams, No. 84-2646-Civ-Marcus, 1986 WL 20915, at *5

(S.D. Fla. Sept. 17, 1986) (finding evident partiality where an arbitrator failed to

disclose that, concurrent with the arbitration, he was representing a plaintiff in

another, unrelated litigation against the insurance company, who was the defendant

in the arbitration), with Lozano v. Maryland Cas. Co., 850 F.2d 1470, 1472 (11th

Cir. 1988) (contrasting the facts in its case with those in Williams and finding that

no evident partiality existed where an arbitrator failed to disclose his law firm’s

representation of adversaries of the arbitral defendant in two state court cases,

partly because “there [was] no evidence that [the arbitrator] was even aware that

these cases existed or that the two cases were . . . active at the time the arbitration

                                           19
proceedings took place.”) Whether he acts as co-counsel or opposing counsel in a

mediation, litigation or other arbitration, the arbitrator could seem biased, and his

ruling in the arbitration could be seen as a way to curry favor in the other matter.

For this reason, we are troubled by appellants’ claim that Meyerson, while the

arbitration was ongoing, represented a co-defendant in the state court case of The

Parliament House, LLC v. Danny Lee Munden d/b/a Painting by Munden with

David Pugh, a Bradley Arant attorney who individually represented University

Commons. If this allegation is true, then Meyerson, at least, would have appeared

to be biased towards University Commons in its dispute with Universal and

Reliance. Admittedly, “the mere appearance of bias or partiality is not enough to

set aside an arbitration award,” Lifecare Int’l, 68 F.3d at 433, but it should have

been enough to require the district court to hold an evidentiary hearing.

      Of course, this, or any other, instance of alleged partiality would be moot if

Meyerson had disclosed it to the parties. Had Universal or Reliance failed to

contest Meyerson’s status as an arbitrator at that time, they would have waived the

right to object in the future. Waiver, however, “applies only where a party has

acted with full knowledge of the facts,” Levine, 675 F.2d at 1204, and, as the

record in this case stands now, it seems unlikely that Universal or Reliance knew

the extensive nature of Meyerson’s previous and concurrent interactions with the

                                          20
lawyers of Bradley Arant at the time of the arbitration. The affidavits that have

been submitted by the parties simply say, without detail, that Meyerson indicated

that “he knew and worked with the law firms representing the parties in this

arbitration;” there is no suggestion that he provided any specific details about these

interactions, including the fact that one was ongoing.

      As we noted earlier, Gianelli Money Purchase Plan & Trust holds that one

scenario under which an arbitration award could be vacated would be if “the

arbitrator knows of, but fails to disclose, information which would lead a

reasonable person to believe that a potential conflict exists.” Gianelli Money

Purchase Plan & Trust, 146 F.3d at 1312 (citations omitted). This standard can be

further distilled into three key elements: (1) the arbitrator must be aware of the

facts comprising a potential conflict; (2) the potential conflict must be one that a

reasonable person would recognize; and (3) the arbitrator must fail to disclose the

conflict. While we did not make it clear in Gianelli Money Purchase Plan & Trust,

it seems logical that, like the second element, the third element – whether or not the

arbitrator disclosed the conflict – should be governed by a reasonable person

standard. In other words, for an award to be vacated, the arbitrator must not have

disclosed enough information for a reasonable person to realize that a potential

conflict existed. Otherwise, the party would have – or, at least, should have –

                                          21
recognized the conflict at the time of the disclosure, and promptly objected.

      In the case at hand, Universal and Reliance have presented prima facie proof

of each of these elements. First, Meyerson knew or should have known that a

potential conflict existed, as soon as David Pugh, his co-counsel in a pending state

court action, appeared before the arbitral panel as counsel for University

Commons.9 After all, serving as the decision-maker in one action in which a

colleague in another action represents a party clearly poses the possibility of bias,

and thus represents a potential conflict that a reasonable person would easily

recognize. Moreover, as the record appears before us, Meyerson did not disclose

the relationship to the parties with enough specificity for them reasonably to

understand that a potential conflict existed. In sum, Meyerson’s alleged actions

constituted prima facie grounds for vacatur of the arbitration award.

      At this point, the district court should have plunged headlong into

evidentiary fact-finding. See Legion Ins. Co. v. Ins. Gen. Agency, Inc., 822 F.2d

541, 542-43 (5th Cir. 1987) (“[S]ome motions challenging arbitration awards may

      9
         In his declaration, Meyerson noted that, at the time of his appointment to
the arbitration panel, only James Archibald and Ron Robey were listed as counsel
for the parties (i.e., Archibald for University Commons and Robey for Universal).
This fact may show why Meyerson initially did not believe he had a potential
conflict with either party, but it does not explain why he did not disclose his
relationship with Pugh once he learned that Pugh would be participating in the
arbitration.
                                          22
require evidentiary hearings outside the scope of the pleadings and arbitration

record. . . . Such matters as misconduct or bias of the arbitrators cannot be gauged

on the face of the arbitral record alone.”); In re Sanko S.S. Co., Ltd. v. Cook

Indus., Inc., 495 F.2d 1260, 1262-63 (2d Cir. 1973) (finding discrepancies

regarding an arbitrator’s possible conflicts and his disclosures about those

conflicts, and deciding that “[t]hese discrepancies require that [the] case be

remanded so that an evidentiary hearing may be held and the full extent and nature

of the relationships at issue may be ascertained.”) University Commons and

Capstone Development could have presented evidence to rebut the prima facie case

set forth by Universal and Reliance, either by contesting the factual accuracy of

their claims or by somehow demonstrating facially that no undisclosed, potential

conflict existed even if the facts Universal and Reliance allege are true. Likewise,

however, Universal and Reliance could have tried to provide proof that Meyerson’s

interactions with Bradley Arant, which, by themselves, do not establish a potential

conflict, are part of an established, ongoing relationship between appellee’s

counsel and himself, which, indeed, might pose a potential conflict. Of course,

discovery would have been needed as to all of these issues.

      Unfortunately, the district court took none of these steps. Instead, as soon as

it grasped the somewhat complex task at hand, or in its own words, “where this

                                          23
was going to lead,” it chose to curtail any evidentiary inquiry and rely upon an

order it had recently issued in another case, Clark v. Alfa Insurance Company, for

the proposition that contacts outside of an arbitration between an arbitrator and a

counsel for a party to that arbitration do not pose a conflict of interest.10 As our

      10
           Specifically, at the hearing, the district court said:

             In the Clark v. Alfa case, the plaintiff’s lawyer in this case had,
      according to the allegations of the motion to disqualify him filed by
      Alfa, then a mediator in a case involving Alfa, and a similar case to
      this one in which some of the issues were the same, perhaps some of
      the cast of characters were the same, and Alfa’s position was that the
      familiarity with the modus operandi of Alfa acquired by plaintiff’s
      lawyer as a mediator, albeit a successful mediator, and in particular, a
      successful mediator who spent considerable time exploring the
      various aspect of that particular matter, gave him an unfair advantage
      because he now knows, according to Alfa, how they think. And that
      gives him an advantage that is undue and presents a conflict of
      interest.

              I said in my opinion that it was close and that it was difficult
      and that I couldn’t find any cases right on point. And I couldn’t.
      There might be some, but I didn’t find them. But after struggling with
      it, I reached the conclusion that the lawyer for the plaintiff was not
      disqualified. And basically my rationale was the domino effect. How
      far does it go?

              Does the plaintiff’s lawyer in this case, does his former law
      firm with which he was affiliated when he was a mediator, is it
      disqualified against Alfa and in what kind of cases? And are all
      members of his present firm disqualified even though they weren’t
      affiliated with him at the time he was a mediator?

               And I said, or I should have said, I think I did say, that under
                                             24
previous discussion intimates, we disagree with this theory of law. Rather, we

believe that interactions between an arbitrator and a party’s counsel, especially

      that theory a person who holds himself out as a mediator should
      anticipate that that’s all he can ever do, be a mediator. He’s got to be
      in a pure mediating firm. And people like Rodney Max, I didn’t call
      his name in there, who constantly and 100 percent mediate, are
      infecting their firm with the inability to represent anybody in a case in
      which Rodney has been the mediator. So that you are going to create
      a narrow focus of people who can only mediate.

             Well, I think maybe that rationale applies to arbitrators. So that
      if Ed Meyerson is competing with Rodney Max, except Rodney, while
      he does arbitration, he predominantly mediates, and Ed, I think,
      predominantly arbitrates, although he mediates too. But anytime he
      does that, and he’s a member of a law firm, if you take that to its
      logical conclusion, or illogical conclusion, depending on how you
      want to view it, it creates an insurmountable problem of the kind that
      now is apparent in this case where the party who is seeking to avoid
      the effect of the arbitration award is suggesting and asking about
      every case in which Ed Meyerson has an interest as an arbitrator. And
      he’s had a lot of them. And whether he’s going to be faced with this
      kind of question of his ability to sit as an arbitrator in every case
      before and after the arbitration is a big question.

              I guess what I’m saying is I’m ready to back up and rethink.
      And it may be, it may be precipitated if I rethink it, not by necessarily
      agreeing now summarily and immediately to enforce the arbitration
      award and to dismiss the attack on the arbitration, but to recognize the
      horror and to disallow and stop it of exploring this and without regard
      to all the niceties.

Unfortunately, the district court’s order in Clark was neither published in the
federal reporters nor entered into the record of the instant case, so we are unable to
review it.
                                          25
those concurrent with the arbitration, can pose a potential conflict. Although

normally we might apply a new standard like this one to the factual findings of the

district court – even as we are constrained to review those findings only for abuse

of discretion – we cannot do so in this case, because the record is bereft of such

findings. Therefore, we must leave this job in the hands of the district court on

remand.

                                          2.

      As a second basis for its assertion that Meyerson’s role as an arbitrator was

compromised by evident partiality, Universal and Reliance have pointed to the

meeting between Meyerson and Capstone Building. The district court made no

mention of this potential source of conflict during the hearing it held on February

28, 2001, and thus, we cannot be certain what, if any, its thoughts were regarding

it. Moreover, as with the other allegations in this case, the record is somewhat

murky as to many facts regarding the meeting. Nevertheless, what we already

know is somewhat troubling.

      Evidently, sometime between the time that Meyerson was appointed as an

arbitrator in University Commons-Urbana, Ltd. c/o Capstone Development Corp.

and Universal Constructors, Inc. and the commencement of the arbitration,

Meyerson met with Jay Chapman, president of Capstone Building. According to

                                          26
Meyerson,11 Chapman merely wanted to consult with Meyerson as to “whether his

attorney at the time was handling an OSHA complaint properly.” Meyerson also

concedes, however, that Chapman asked him “whether [his] firm was able to do

some corporate work for him in the future,” but Meyerson declined.

      Normally, that an arbitrator meets with a non-party about other business

during the course of the arbitral process would hardly suggest evident partiality.

This assumption presupposes, though, that a non-party would not have a pecuniary

interest in the arbitration. Such may not be the case here. Approximately

$500,000 of the damages University Common sought from Universal and Reliance

involved the cost of work performed by Capstone Building to complete the Project.

More importantly, Mike Mauron, the owner of Capstone Development, owns forty-

nine percent of Capstone Building. Put another way, a party to the arbitration, with

a significant stake in Meyerson’s decision-making, owned nearly half of Capstone

Building. Had the district court allowed discovery to continue, there is a chance

that more evidence may have come to light showing an even closer affiliation

      11
         On February 27, 2001, one day before the district court’s scheduled
hearing in this case, Meyerson filed a declaration, along with a motion to quash a
deposition subpoena that had been issued to him. Based on the court’s comments
at that hearing, however, it is clear that the court decided to confirm the arbitration
award before it had seen either the declaration or the motion and, therefore, found
both to be moot.
                                          27
between Capstone Building and Capstone Development.12

      The connection between these two companies is not the only subject on

which further fact-finding is necessary. We need additional information on

Meyerson’s disclosure of his meeting with Capstone Building. Unlike our

foregoing discussion of Meyerson’s disclosures about his previous legal

interactions with Bradley Arant, however, we are not interested as much in what he

said about his meeting with Capstone Building – both parties acknowledge that

Meyerson told them he had met with a representative of Capstone Building about

possible employment – as when he said it. Our reasons are twofold. First, whether

Meyerson knew or should have known about a close affiliation between Capstone

      12
         For example, Universal and Reliance have cited two articles in the
Birmingham Business Journal that purportedly demonstrate a close relationship
between Capstone Building and Capstone Development. The first reveals that
Mauron purportedly started Capstone Building “as an offshoot of Capstone
Development” and only gave Chapman, whom Mauron hired to run Capstone
Building, a majority share of the ownership, when the workload became greater
than either had originally planned. Carol Muse Evans, Chapman’s Dream Now
His Reality, Birmingham Bus. J., June 9, 2000, at 7. The second article quotes
Chapman as admitting that “[t]he genesis of [Capstone Building] was to service
[Mauron’s] projects,” with Mauron elaborating that “Capstone Development uses
capstone Building as its general contractor as much as possible.” Don Milazzo,
Fast Track 25 Winners Reveal Success Stories, Birmingham Bus. J., May 5, 2000,
at 8. Universal and Reliance have also alleged that, according to Capstone
Building’s portfolio, all of Capstone Building’s completed and ongoing projects
were developed by Capstone Development. Neither the articles nor the portfolio
have been made a part of the record, however.
                                        28
Building and Capstone Development at the time he made his disclosure is

obviously relevant. After all, an arbitrator can only be held culpable for what he

knows or should know, but fails to disclose. Also relevant is whether Meyerson

delayed disclosing the meeting until it was unreasonable for Universal and

Reliance to object to his participation in the arbitration. An arbitrator must

disclose a potential conflict as soon as it becomes apparent; otherwise, delay and

concealment would be encouraged. Cf. Levine, 675 F.2d at1204 (“To hold . . . that

[a party] waived [its] right to contest the alleged impartiality of the neutral

arbitrator because [it] did not discover evidence of partiality prior to arbitration

would put a premium on concealment.”) Meyerson claims he met with Chapman

after he was appointed to the arbitration panel, but the parties disagree on when

Meyerson informed them of this meeting; both University Commons and

Meyerson claim that this disclosure occurred at the onset of the arbitration, while

Universal and Reliance assert that Meyerson’s announcement came during the

second set of hearings. If the district court finds that Meyerson delayed making his

disclosure until the arbitration had proceeded to the point that, given the amount of

funds and resources they had invested in the proceeding, Universal and Reliance

could not, as a practical matter, afford to object to Meyerson continuing as a

member of the arbitration panel, then the court may well decide that Meyerson’s

                                           29
disclosure was insufficient to avoid vacatur.

                                          3.

      The third and final ground Universal and Reliance provide for claiming that

Meyerson was compromised by evident partiality involves his belated recognition

of Jeff Schattinger, an allegedly “principal” witness for University Commons.

Schattinger was one of the most important witnesses to testify in the arbitration

proceeding. When he appeared before the panel, Meyerson acknowledged that he

had met him on a prior occasion. After the arbitration ended, Meyerson clarified

that he had met Schattinger several years earlier during an arbitration proceeding,

in which Meyerson was counsel and Schattinger testified as an expert witness for

the opposing party.

      Nevertheless, even without this late information, there was nothing so

suspicious about the relationship between Meyerson and Schattinger – if it can be

called a “relationship” – that should have prompted the district court to elicit

further information. Meyerson merely realized, at the moment he first saw the

witness face-to-face, that he had encountered him previously. Nothing about this

fact suggests that Meyerson would have been partial to one side or the other as a

                                          30
result. In fact, Meyerson’s inability to recognize Schattinger until he appeared

before the arbitration panel demonstrates the insignificance of their previous

encounter. We cannot require district courts to review arbitration results every

time an arbitrator discovers that a mere acquaintance is a witness. Hence, we find

that the district court acted appropriately in finding that Meyerson’s recognition of

Schattinger did not represent prima facie grounds of evident partiality.

                                         III.

      In summary, while Universal and Reliance have not provided any grounds

for its claim that the arbitration award in University Commons-Urbana, Ltd. c/o

Capstone Development Corp. and Universal Constructors, Inc. represented a

manifest disregard for the law, they have identified two separate bases for a prima

facie case that the award should be vacated due to Meyerson’s evident partiality:

(1) his previous and – more problematically – concurrent legal interactions with

the individual lawyers who represented University Commons in the arbitration, and

(2) his meeting with Chapman, the president of Capstone Building. Nevertheless,

due to the paucity and incomplete nature of the record before us, we cannot say

whether vacatur is indeed warranted. “[T]he ‘evident partiality’ question

                                         31
necessarily entails a fact intensive inquiry [as t]his is one area of the law which is

highly dependent on the unique factual settings of each particular case.” Lifecare

Int’l, 68 F.3d at 435. What is needed now, therefore, is, an evidentiary hearing on

these two allegations (in which we have found merit). From the evidence adduced

at the hearing, the district court must determine two things: the relevant facts, and

whether Meyerson adequately disclosed such facts. The district court’s

confirmation of the arbitration award is therefore VACATED and the case is

REMANDED for further proceedings.

      SO ORDERED.

                                           32