Court Opinion

ID: 7360959
Source: CourtListenerOpinion
Date Created: 2022-07-26 21:05:19.086661+00
Date Added: 2024-06-11T16:20:33.743706
License: Public Domain

07/26/2022

                                         DA 21-0604
                                                                                       Case Number: DA 21-0604

              IN THE SUPREME COURT OF THE STATE OF MONTANA
                                         2022 MT 149

M.K. WEEDEN CONSTRUCTION, INC.,

               Applicant and Appellee,

         v.

SIMBECK AND ASSOCIATES, INC.,

               Respondent and Appellant.

APPEAL FROM:           District Court of the Eighteenth Judicial District,
                       In and For the County of Gallatin, Cause No. DV-21-204C
                       Honorable John C. Brown, Presiding Judge

COUNSEL OF RECORD:

                For Appellant:

                       Matthew A. Haus, Tarlow Stonecipher Weamer & Kelly, PLLC, Bozeman,
                       Montana

                For Appellee:

                       Fred Simpson, Jenks & Simpson, P.C., Missoula, Montana

                                                  Submitted on Briefs: May 11, 2022

                                                              Decided: July 26, 2022

Filed:

                                 c ir-641.—if
                       __________________________________________
                                         Clerk
Justice Jim Rice delivered the Opinion of the Court.

¶1     Simbeck and Associates, Inc. (Simbeck) appeals from the Findings of Fact,

Conclusions of Law, and Order (Order) entered by the Eighteenth Judicial District Court,

vacating the Arbitrator’s Interim Award and Final Award, and requiring the parties to

resubmit their dispute to arbitration before a new arbitrator. The issues on appeal are:

       1. Did the District Court err by vacating the Arbitrator’s award and ordering a
       new arbitration?

       2. Is Simbeck entitled to attorney fees incurred in litigation before the District Court
       and on appeal?

       We reverse the District Court’s Order and remand for a determination of attorney

fees incurred by Simbeck in defense of the arbitration award before the courts.

                 FACTUAL AND PROCEDURAL BACKGROUND

¶2     In April 2019, M. K. Weeden Construction, Inc. (Weeden), entered into a contract

with Stillwater Mining Company to raise the embankments on a tailings storage facility at

the East Boulder Mine near Nye, Montana. In October 2019, Weeden and Simbeck entered

a contract (Subcontract) for Simbeck to install a geosynthetic lining system on the slopes

of the new embankment. Despite the Subcontract being signed in October, it was originally

contemplated that this work would occur in late summer and early fall; the Subcontract

itself did not provide a timeframe or deadline by which Simbeck would complete the

project. Delays on the project ensued to the extent that most of Simbeck’s work was pushed

into the winter months, and harsh weather conditions limited the work Simbeck could

perform on the site. Weeden and the mine owner became concerned about Simbeck’s pace

                                              2
on the project and, without informing Simbeck, Weeden contracted with H2J Installers

(H2J) to perform the same lining work Simbeck had contracted to perform. When Simbeck

learned that H2J had been hired to perform the same work, and believing Weeden intended

to replace Simbeck with H2J, Simbeck removed its equipment and workers from the

project. Simbeck conveyed to Weeden that it would return to the project upon certain

conditions, but Weeden refused and terminated the Subcontract by invoking the

Subcontract’s default provision.

¶3     In January 2020, Simbeck filed a demand for arbitration, pursuant to the

Subcontract, with the American Arbitration Association (AAA).                   Weeden filed a

counterclaim, resulting in both parties claiming the other had breached the Subcontract and

the covenant of good faith and fair dealing, among other claims. At a preliminary hearing

with the Arbitrator, the parties agreed the Arbitrator would issue a “reasoned award”—a

reference to the form of decision. This stipulation of the parties was reflected in the

Arbitrator’s scheduling order. After a proceeding on the merits, the Arbitrator issued an

Interim Award, concluding that Weeden materially breached the contract when it hired H2J

to perform the same work as Simbeck.1 The Interim Award awarded Simbeck $337,431.40

in damages. After consideration of attorney fees and costs, the Arbitrator issued a Final

1
 The Arbitrator also concluded Weeden had breached the covenant of good faith and fair dealing
by withholding certain payments from Simbeck. The parties placed little significance on this
determination before the District Court or on appeal, and, therefore, we do not further address it.

                                                3
Award, which awarded Simbeck an additional $198,032 in attorney fees and $62,314.83

in various other costs, thus rendering a total award of $597,778.23.

¶4     Weeden filed a petition to vacate the arbitration award in the District Court, and

Simbeck responded with a motion to confirm the award. After a hearing, the District Court

vacated the award, concluding the Arbitrator exceeded his authority by issuing an Interim

Award that did not satisfy the standards for a “reasoned opinion” because it did not contain

“a shred of legal analysis or ‘discussion of the law as applied to the facts of the case,’” did

not specifically reference which part of the Subcontract Weeden had breached, and

improperly relied on the parties’ subjective opinions regarding the Subcontract. The

District Court vacated the Interim and Final Awards and ordered the parties to again submit

the dispute to arbitration before a new arbitrator.

                                STANDARD OF REVIEW

¶5     “Montana’s Uniform Arbitration Act [(MUAA)] strictly limits a district court’s

review of an arbitration award.” Sutey Oil Co. v. Monroe’s High Country Travel Plaza,

L.L.C., 2022 MT 50, ¶ 8, 408 Mont. 69, 506 P.3d 310 (citing Tedesco v. Home Sav.

Bancorp, Inc., 2017 MT 304, ¶ 11, 389 Mont. 468, 407 P.3d 289). “We review district

court decisions on arbitration awards like any other district court decision, accepting

findings of fact that are not clearly erroneous but deciding questions of law de novo.”

Tedesco, ¶ 11 (citing City of Livingston v. Mont. Pub. Emps. Ass’n ex rel. Tubaugh, 2014

MT 314, ¶ 11, 377 Mont. 184, 339 P.3d 41). “A finding is clearly erroneous if it is not

supported by substantial evidence, the district court misapprehended the effect of the

                                              4
evidence, or our review of the evidence convinces us that the district court made a mistake.”

In re Marriage of Tummarello, 2012 MT 18, ¶ 21, 363 Mont. 387, 270 P.3d 28 (citation

omitted). “We review for an abuse of discretion the court’s ultimate decision to confirm

an arbitration award.” Sutey Oil, ¶ 8 (citing Tedesco, ¶ 11). “In reviewing whether the

District Court abused its discretion in confirming the arbitration award, we apply the law

that a court cannot review the merits of the controversy, but may only confirm, vacate,

modify, or correct an arbitration award pursuant to §§ 27-5-311, -312, and -313, MCA.”

Tedesco, ¶ 12 (citing Roberts v. Lame Deer Pub. Sch. Dist. #6, 2013 MT 358, ¶ 7, 373

Mont. 49, 314 P.3d 647).

                                       DISCUSSION

¶6     1. Did the District Court err by vacating the Arbitrator’s award and ordering a
       new arbitration?

¶7     Montana law grants to arbitrators broad authority to decide “all issues” of a

submitted dispute. City of Livingston, ¶ 14 (citation omitted). A corollary is the settled

rule that “a court’s power to vacate an arbitration award must be extremely limited”

because overly expansive review would “undermine the litigation efficiencies which

arbitration seeks to achieve.” Sutey Oil, ¶ 16 (quoting City of Livingston, ¶ 14). “As long

as an arbitrator’s factual determination and legal conclusions derive their essence from the

[contract] itself and the award represents a plausible interpretation of the contract, judicial

inquiry ceases and the award must be enforced.” City of Livingston, ¶ 15 (citing Sheet

Metal Workers Int’l Ass’n, Local No. 359 v. Arizona Mechanical & Stainless, Inc., 863

F.2d 647, 653 (9th Cir. 1988)).
                                              5
¶8     The MUAA provides, in relevant part, that a district court shall vacate an award if:

“(b) there was evident partiality by an arbitrator appointed as a neutral or corruption in any

of the arbitrators or misconduct prejudicing the rights of any party; [or] (c) the arbitrators

exceeded their powers.” Section 27-5-312(1)(b), (c), MCA. We have held that “when an

arbitrator is aware of a clearly governing principle of Montana law, and blatantly refuses

to follow it,” the § 27-5-312(1)(b), MCA, condition is satisfied. Terra W. Townhomes,

L.L.C. v. Stu Henkel Realty, 2000 MT 43, ¶ 35, 298 Mont. 344, 996 P.2d 866 (quoting

Geissler v. Sanem, 285 Mont. 411, 416, 949 P.2d 234, 237-38 (1997)). Because an

arbitrator’s authority is “limited by the bounds of the [arbitration] agreement,” arbitrators

exceed their power under § 27-5-312(1)(c), MCA, when they issue an award “that extend[s]

beyond the contractual scope of arbitration” by “decid[ing] matters which were not

submitted to [them].” Nelson v. Livingston Rebuild Ctr., Inc., 1999 MT 116, ¶¶ 14-15, 294

Mont. 408, 981 P.2d 1185 (citation omitted). On the other hand, “‘if the remedy fashioned

by the Arbitrator has been rationally derived from the [arbitration] agreement it will be

upheld on review.’” Terra W. Townhomes, ¶ 27 (quoting Nelson, ¶ 19).

¶9     Here, the District Court first noted that the briefing submitted during arbitration had

made the Arbitrator “aware of the clearly governing principle of Montana law that the

standard to apply to determine whether a party materially breached a contract is an

objective rather than a subjective standard.” See Davidson v. Barstad, 2019 MT 48, ¶ 23,

395 Mont. 1, 435 P.3d 640 (quoting 23 Richard A. Lord, Williston on Contracts § 63:3 (4th

ed. 2018)) (“Whether a breach is material or not is a matter of ‘objective reasonableness

                                              6
rather than’ the non-breaching party’s ‘purely subjective belief.’”). The District Court

adopted Weeden’s position that the Arbitrator wrongly applied a subjective standard in

determining whether the breach was material, citing to several paragraphs in the Interim

Award:

       12. Perspective is material to the decision as to which party breached the
       subcontract agreement.

                                          .   .   .

       21. From [Simbeck’s] perspective, it was aware that there was frustration on
       everyone’s part about the speed of the performance of the lining work in
       November and December. . . .

       22. From [Simbeck’s] perspective, when it learned on December 12th from
       H2J (and not [Weeden]) that H2J was being hired, without notice to or
       discussion with [Simbeck] to perform lining work on the site, it was
       reasonable under the circumstances and history of dealings between
       [Weeden] and [Simbeck], that [Simbeck] believed that [Weeden] was
       intending to replace [Simbeck] with H2J.

                                          .   .   .

       31. From [Simbeck’s] perspective, it was not intending to abandon its
       contractual obligations with [Weeden]. From [Simbeck’s] perspective, the
       removal of the equipment was a protective measure it was taking in light of
       the actions of [Weeden].

(Emphasis original.) Noting the references therein to “Simbeck’s perspective,” the District

Court concluded that “[t]he Interim Award is rife with the Arbitrator’s findings of

[Simbeck’s] subjective beliefs, but utterly lacking in the required objective analysis of the

material breach issue.” However, we do not see this conclusion borne out from a full

reading of the Interim Award.

                                              7
¶10    The Arbitrator indeed made findings regarding the parties’ subjective beliefs about

actions on the project site and interactions with each other, but these were not the ultimate

basis for the Arbitrator’s findings regarding whether a material breach had occurred.

Rather, they provided context for the Arbitrator’s ultimate conclusions about breaches of

the contract and the covenant of good faith and fair dealing, as reflected in the Arbitrator’s

finding regarding material breach in Paragraph 19 of the Interim Award: “[w]hile . . .

[Weeden] did not intend to breach the subcontract with [Simbeck] by hiring H2J, [Weeden]

did breach the subcontract by hiring H2J to perform a material portion of the scope of the

[Simbeck] subcontract.”     Thus, when read in the context of the entire Award, the

Arbitrator’s finding was that, despite Weeden’s subjective beliefs, it objectively breached

the Subcontract by hiring H2J. Relative to material breach, Paragraph 19 conveys that

(1) Weeden indeed hired H2J; (2) Weeden hired H2J to perform a material portion of the

Subcontract, which Simbeck had a contractual right to perform; and (3) in doing so,

Weeden materially breached the Subcontract. These are objective findings regarding

material breach that are not dependent upon the parties’ subjective views. See Ferdig Oil

Co. v. ROC Gathering, L.L.P., 2018 MT 307, ¶ 12, 393 Mont. 500, 432 P.3d 118 (“The

determination of whether a party materially breached a contract is a question of fact.”). We

cannot conclude from this review that the Arbitrator “blatantly refuse[d]” to follow

established Montana law, and thus the statutory basis for vacatur under § 27-5-312(1)(b),

MCA, is not satisfied. See Terra W. Townhomes, ¶ 35; Tedesco, ¶ 12.

                                              8
¶11    The District Court also concluded that, under § 27-5-312(1)(c), MCA, the Arbitrator

exceeded the power granted to him under the arbitration agreement by failing to issue a

“reasoned opinion.” As an initial matter, Simbeck argues the District Court erroneously

categorized the form of the award the parties requested from the Arbitrator as a “reasoned

opinion” rather than a “reasoned award.” This point is not insignificant, as much of the

District Court’s analysis is based upon its determination of what constituted an “opinion.”

The parties conducted the arbitration pursuant to the AAA Construction Industry

Arbitration Rules and Mediation Procedures (AAA Rules). AAA Rule 47(c) provides that

parties may “request a specific form of award, including [1] a reasoned opinion, [2] an

abbreviated opinion, [or 3] findings of fact, or conclusions of law [sic], but may also agree

upon a different form of award,” and that “the Arbitrator shall provide the form of award

agreed upon.” The District Court noted the arbitration scheduling order had provided

“[t]he Arbitrator shall issue a Reasoned Award at the conclusion of these proceedings” and

found that “[t]he form of award was never changed.” Yet, despite finding that a “reasoned

award” had been requested by the parties, the District Court then stated, “the parties and

the Arbitrator intended and agreed that the Arbitrator would issue a ‘reasoned opinion.’” 2

2
  A “reasoned award” is not explicitly mentioned in the version of the AAA Rules used here, but
is referenced in previous versions of the AAA Rules and the AAA Commercial Arbitration Rules
and Mediation Procedures. See Stage Stores, Inc. v. Gunnerson, 477 S.W.3d 848, 856-57 (Tex.
App. 2015). In any event, under AAA Rule 47(c), (1) an alternate form of award can be requested
by the parties, and (2) “[a]fter the conclusion of the Preliminary Management Hearing, the parties
may not change the form of the award without the arbitrator’s express consent” with the arbitrator
“confirm[ing] the nature of the change to the form of award.” Here, the form of award was never
changed from the originally designated “reasoned award.”

                                                9
The District Court’s finding that the parties requested a “reasoned opinion” clearly

contradicts the language of the arbitration scheduling order and must be considered clearly

erroneous. In re Marriage of Tummarello, ¶ 21.

¶12    Having determined the Arbitrator was obligated to issue a “reasoned award,” we

next consider whether the Interim Award satisfied that standard. The AAA Rules do not

define a “reasoned award,” nor do the parties point to any part of the Subcontract or

arbitration proceedings that provided a definition for the term. Other courts, however, have

concluded that a “reasoned award” falls somewhere between an abbreviated or standard

award, which simply declares the prevailing party and any damages awarded, and a

complete set of findings of fact and conclusions of law. Leeward Constr. Co. v. Am. Univ.

of Antigua - Coll. of Med., 826 F.3d 634, 638 (2d Cir. 2016) (citations omitted) (a “reasoned

award” contains something short of findings of fact and conclusions of law but more than

a simple result); Gunnerson, 477 S.W.3d 848, 858 (citations omitted) (“the detail and

specificity required of a ‘reasoned award’ falls between a standard award and findings of

fact and conclusions of law”); Rain CII Carbon, LLC v. ConocoPhillips Co., 674 F.3d 469,

474 (5th Cir. 2012) (a “reasoned award” is more than a “simple result” but less than

findings of fact and conclusions of law).         While these cases addressed arbitrations

conducted under the Federal Arbitration Act, we find their explanations regarding a

“reasoned award” to be persuasive. A “reasoned award” is “an award that is provided with

or marked by the detailed listing or mention of expressions or statements offered as a

justification” for the arbitrator’s decision, but less than complete findings of facts and

                                             10
conclusions of law. Gunnerson, 477 S.W.3d at 858-59 (quoting Cat Charter, LLC v.

Schurtenberger, 646 F.3d 836, 844 (11th Cir. 2011)).

¶13    Clearly, the Interim Award issued here by the Arbitrator does more than simply

declare a prevailing party and assess damages. The document is over fourteen pages long,

including nine pages of the Arbitrator’s exploration of the facts and his resolution of the

parties’ claims, with the remainder providing the Arbitrator’s rationale regarding the

damages award. Yet, while more than a standard award, the Interim Award is less than a

formal set of findings of fact and conclusions of law with citations to legal authority.

“[F]indings of fact and conclusions of law are not [a] judgment, but . . . the foundation for

[a] judgment.” In re Marriage of Barron, 177 Mont. 161, 164, 580 P.2d 936, 938 (1978)

(citing State ex rel. King v. Dist. Court, 107 Mont. 476, 480, 86 P.2d 755, 757 (1939)).

“This foundation need not consist of a multitude of evidentiary facts, but must be

comprised of ultimate facts.” Wareing v. Schreckendgust, 280 Mont. 196, 207, 930 P.2d

37, 44 (1996) (quoting Barron, 177 Mont. at 164, 580 P.2d at 938). The Interim Award

contains the Arbitrator’s ultimate factual determinations on the issues for which damages

were awarded, most pertinently breach of contract, but omits discussion of other issues,

such as Simbeck’s claims of constructive fraud and negligent misrepresentation, for which

the Arbitrator apparently did not find Weeden liable, and thus was not complete

conclusions of law.

¶14    However, we conclude the Interim Award was sufficient to constitute a “reasoned

award” under the arbitration rules governing this proceeding. It provided a detailed listing

                                             11
of the Arbitrator’s impressions and statements regarding the parties’ actions and conduct

relative to the dispute, and his legal justification for the granted damage award—namely,

that Weeden breached the Subcontract. While at times the Arbitrator’s reasoning might

not be entirely explicit, it was nonetheless understandable given a fair reading and the

deference we afford an arbitrator’s decisions. See City of Livingston, ¶ 14 (“Montana gives

arbitrators broad authority and powers to determine all issues . . . a court’s power to vacate

an arbitration award must be extremely limited because an overly expansive judicial review

of arbitration awards would undermine the litigation efficiencies which arbitration seeks to

achieve.”) (citation omitted).

¶15    The District Court adopted Weeden’s contention that the Interim Award failed to

reference specific provisions of the Subcontract or cite to any caselaw, statutes, or other

legal authority. These arguments pivot from the question of the award’s form and instead

challenge its substance.    As noted above, an arbitrator exceeds his authority under

§ 27-5-312(1)(c), MCA, by issuing an award in a form other than that agreed upon by the

parties. “Whether an award is a ‘reasoned award’ is a question of form, not substance.”

Gunnerson, 477 S.W.3d at 859. Aside from whether, pursuant to § 27-5-312(1)(b), MCA,

and Terra West Townhomes, ¶ 35, the arbitrator “blatantly refuses” to follow established

Montana law, we will not overturn an award “simply because the arbitrator may have

misapplied the law.”     Sutey Oil Co., ¶ 16 (quoting Terra West Townhomes, ¶ 37).

Consequently, unless an arbitrator’s lack of citation to legal authority in this form of

decision amounts to a blatant refusal to follow established law, it does not, without more,

                                             12
provide a basis to overturn an otherwise proper “reasoned award.” The primary legal issue

here, and the basis of the Arbitrator’s award, was breach of contract. To resolve that issue,

the Arbitrator needed, under the arbitration agreement, to apply the facts found from the

evidence presented by the parties to the four corners of the Subcontract, which did not

necessarily require citation to legal authority under the arbitration rules. See Ferdig Oil

Co., ¶ 12. The Arbitrator’s general references to the Subcontract were likewise sufficient.

The statement that “[Weeden] did breach the subcontract by hiring H2J to perform a

material portion of the scope of the [Simbeck] subcontract” is an obvious, though informal,

reference to the Subcontract’s “Scope of Work” provision. Reading that provision in

conjunction with the Arbitrator’s reasoning provides a clear explanation for why the

Arbitrator deemed Weeden to have breached the Subcontract.

¶16    We thus conclude the Interim Award is in form a proper “reasoned award”—the

award the parties agreed to—and the District Court abused its discretion by vacating it

pursuant to § 27-5-312(1)(c), MCA. See Tedesco, ¶ 12.

¶17    2. Is Simbeck entitled to attorney fees incurred for litigation before the District
       Court and on appeal?

¶18    Simbeck argues that, should it prevail on appeal, it is entitled to attorney fees

incurred in the litigation before the District Court and on appeal regarding the arbitration

award, pursuant to § 28-2-2105, MCA, part of the Prompt Payment Act. That provision

states, in relevant part: “[i]n a civil action on a contract to enforce an obligation imposed

by this part, the prevailing party is entitled to reasonable attorney fees and costs, both for

trial and appeal.” The Subcontract itself does not provide that a prevailing party in the
                                             13
dispute is entitled to attorney fees; rather, fees were awarded by the Arbitrator for fees

incurred in arbitration based upon the parties’ agreement that the Arbitrator was

empowered to award them.

¶19    Weeden argues that in Terra West Townhomes this Court concluded that “there is

no statutory or contractual basis for an award of attorney fees” under the MUAA, and

therefore, absent any contractual agreement, attorney fees before the District Court and on

appeal are not proper.     See Terra West Townhomes, ¶ 41.            However, Terra West

Townhomes, decided in 2000, involved contracts entered between 1995 - 1997. Terra West

Townhomes, ¶¶ 7-16. These contracts were thus entered before the Prompt Payment Act’s

effective applicability date of July 1, 1999. See 1999 Mt. Laws ch. 470, § 12. This Court

was correct in Terra West Townhomes that, at the time, there was no statutory basis for

attorney fees for those claims. Thereafter, the Prompt Payment Act was enacted, and

expressly provides for an award of “reasonable attorney fees and costs, both for trial and

on appeal” arising from a civil action to enforce an obligation imposed by the Act. Section

28-2-2105, MCA. Weeden argues:

       The Arbitrator’s decision to award attorney’s fees was based upon the
       parties’ stipulation that the Arbitrator had authority to award attorney’s fees.
       That stipulation was based on the AAA Rules, which do not apply to the
       proceeding before the District Court. The proceeding before the District
       Court was governed by Montana’s Uniform Arbitration Act, which does not
       provide for an award of attorney’s fees.

(Internal citations omitted.) However, the MUAA governs only a court’s review of the

arbitration award itself, and whether attorney fees awarded by the arbitrator for that

proceeding were appropriate. Tedesco, ¶ 11; Terra West Townhomes, ¶ 41. Thus, while
                                             14
Weeden’s argument is technically correct regarding an arbitrator’s authority to award

attorney fees, that is not the issue raised here. Rather, the issue is whether Simbeck is

entitled to attorney fees stemming from its now successful defense of the Arbitrator’s

award in litigation before the courts.

¶20    The Court faced the same question in Dick Anderson Constr., Inc. v. Monroe Constr.

Co., L.L.C., 2009 MT 416, 353 Mont. 534, 221 P.3d 675.               There, we concluded

§ 28-2-2105, MCA, applied when a party prevailed on an appeal stemming from an

arbitrated breach of contract claim. Dick Anderson, ¶ 63. We declined to award attorney

fees on appeal, however, for the reason such an award would not be “reasonable” pursuant

to § 28-2-2105, MCA, when the same party had already benefited from a windfall

miscalculation of attorney fees made by the arbitrator. Dick Anderson, ¶ 63. That

corrective circumstance is not present here, where Simbeck prevailed in arbitration, but

was required to defend the award in litigation after it was challenged by Weeden.

¶21    One objective of the Prompt Payment Act is to obligate a contractor to pay its

subcontractors. Section 28-2-2102, MCA. The Interim Award awarded Simbeck “the

unpaid sums billed for the work performed to date” and related damages, along with a 1.5%

interest rate per month until paid. This 1.5% interest rate is derived from § 28-2-2104,

MCA, likewise a part of the Prompt Payment Act. Simbeck prevailed in the private

arbitration action to enforce Weeden’s statutory obligation to pay it for services rendered.

By initiating litigation to challenge the award, Weeden assumed the risk of potential

imposition of attorney fees and costs under § 28-2-2105, MCA. Because it ultimately

                                            15
prevailed on appeal, Simbeck is therefore entitled to attorney fees and costs reasonably

incurred in the litigation pursuant to § 28-2-2105, MCA.

¶22    For the foregoing reasons, the District Court’s Order is reversed. We remand the

matter with instructions for the District Court to enter judgment confirming the Interim and

Final Awards, and for a determination of Simbeck’s reasonable costs and attorney fees

incurred before the District Court and on appeal.

                                                 /S/ JIM RICE

We concur:

/S/ LAURIE McKINNON
/S/ BETH BAKER
/S/ INGRID GUSTAFSON
/S/ DIRK M. SANDEFUR

                                            16