Court Opinion

ID: 3021155
Source: CourtListenerOpinion
Date Created: 2015-10-13 22:24:13.875621+00
Date Added: 2024-06-11T12:45:39.053605
License: Public Domain

Opinions of the United
2006 Decisions                                                                                                             States Court of Appeals
                                                                                                                              for the Third Circuit

6-9-2006

Quinn Constr Inc v. RC Dolner
Precedential or Non-Precedential: Non-Precedential

Docket No. 05-1693

Follow this and additional works at: http://digitalcommons.law.villanova.edu/thirdcircuit_2006

Recommended Citation
"Quinn Constr Inc v. RC Dolner" (2006). 2006 Decisions. Paper 929.
http://digitalcommons.law.villanova.edu/thirdcircuit_2006/929

This decision is brought to you for free and open access by the Opinions of the United States Court of Appeals for the Third Circuit at Villanova
University School of Law Digital Repository. It has been accepted for inclusion in 2006 Decisions by an authorized administrator of Villanova
University School of Law Digital Repository. For more information, please contact Benjamin.Carlson@law.villanova.edu.
                                                               NOT PRECEDENTIAL

                      UNITED STATES COURT OF APPEALS
                           FOR THE THIRD CIRCUIT
                                ____________

                                    No. 05-1693
                                    ____________

                          QUINN CONSTRUCTION, INC.,

                                            Appellant

                                            v.

                       RC DOLNER LLC, doing business as
                        RC DOLNER LLC Construction;
                   LIBERTY MUTUAL INSURANCE COMPANY

                                    ____________

                    On Appeal from the United States District Court
                       for the Eastern District of Pennsylvania
                         D.C. Civil Action No. 02-cv-08883
                          (Honorable William H. Yohn, Jr.)
                                    ____________

                      Submitted Under Third Circuit LAR 34.1(a)
                                   April 28, 2006

     Before: SCIRICA, Chief Judge, NYGAARD, and ALARCÓN,* Circuit Judges

                                 (Filed: June 9, 2006)
                                    ____________

                             OPINION OF THE COURT
                                  ____________

ALARCÓN, Circuit Judge.

      *
        The Honorable Arthur L. Alarcón, Senior Judge, United States Court of Appeals
for the Ninth Circuit, sitting by designation.
       The District Court, following a bench trial in this diversity action, awarded

damages to Quinn Construction, Inc. (“Quinn”) based on its breach of contract suit

against RC Dolner (“Dolner”). Quinn appeals from the portions of the District Court’s

order denying Quinn interest, penalties and attorneys’ fees under the Pennsylvania

Contractor and Subcontractor Payment Act, 73 P.S. § 501 et seq. (2005) (“PCSPA”), and

determining that the prime rate was the proper pre-judgment interest rate. We affirm.

                                               I

       In October 2000, Quinn, a concrete subcontractor, and Dolner, a general

contractor, entered into a contract (“Contract”) whereby Quinn agreed to provide

excavation and masonry work for Dolner. Dolner approved and paid Quinn’s invoices

through November 30, 2001. Quinn continued to perform under the Contract until

February 2002, at which time Quinn demobilized from the project. Even though Quinn

had not completed all of the work under the Contract, Quinn left the job site because it

had done all of the work available to it at that time.

       On October 31, 2002, Quinn submitted a final payment application to Dolner for

the work performed from December 1, 2001 through February 4, 2002. Dolner responded

by letter on November 5, 2002 contesting some of the items billed in Quinn’s invoice and

claiming instead that Quinn had been overpaid by $30,363.

       Quinn sued Dolner for breach of contract, unjust enrichment and quantum meruit

seeking $138,637 plus statutory interest, penalties and attorneys’ fees for Dolner’s alleged

violation of the PCSPA. After a bench trial, the District Court issued findings of fact

                                               2
    setting forth the dollar value of Quinn’s work and ordered the parties to submit an

    accounting of amounts due based on its factual findings. After a hearing, the District

    Court awarded Quinn $92,385; $51,933 representing the amount due for work performed,

    and $40,452 representing 10% of the value of the contract that Dolner was entitled to hold

    as “retainage.” The District Court determined that Quinn was required, under the

    Contract, to sign a final release as a condition to receiving the retainage from Dolner.

    The District Court also concluded that no statutory interest, penalties or attorneys’ fees

    were warranted because Dolner had acted in good faith under the PCSPA and because

    neither party substantially prevailed in the action.

                                                  II

           Quinn contends that the District Court erred in determining that Dolner was not

    subject to the attorneys’ fees, interest or penalty provisions in the PCSPA because Dolner

    acted in good faith when it withheld payments for “deficiency items” as the term is

    defined under the statute. We review a district court’s conclusions of law de novo.

    Henglein v. Colt Industries Operating Corp., 260 F.3d 201, 208 (3d Cir. 2001).1

           Section 504 of the PCSPA provides for the timely payment of contractors and

    subcontractors, imposing penalties where an owner or general contractor fails to comply

    with payment provisions therein. 73 P.S. § 504. Under § 507, a subcontractor is entitled

    to payment upon performance and within fourteen days of receipt of the subcontractor’s

           1
1           Quinn does not challenge any of the District Court’s factual findings on appeal.

                                                  3
invoice, unless payment is being withheld under § 511. Id. at § 507. Section 511 allows

contractors to withhold payment for “deficiency items,” so long as the contractor provides

notice of the disputed items to the subcontractor within seven days. Section 502 defines

“deficiency item” as “[w]ork performed but which the owner, the contractor or the

inspector will not certify as being completed according to the specifications of a

construction contract.” Id. at § 502.

       The District Court found that Quinn submitted its final payment application to

Dolner on October 31, 2002 and that, on November 5, 2002, Dolner informed Quinn by

letter that it disagreed with Quinn’s final accounting and believed Quinn may have been

overpaid. Dolner indicated it was disputing fifteen line items in Quinn’s final invoice

because Dolner believed Quinn had completed a lower percentage of the contract work

than Quinn claimed. Because Dolner complied with the good faith provisions of § 511,

the District Court found that Dolner was relieved of its obligation to pay Quinn within

fourteen days, as required under § 507. Accordingly, the District Court determined that

Dolner had not wrongfully withheld the payments but did so “based on Dolner’s good-

faith belief that Quinn had been deficient in its performance.” Quinn’s argument that the

District Court misinterpreted the PCSPA is unpersuasive. The District Court applied the

plain language of the statute to the facts of this case and determined that because Dolner

satisfied the good faith exception in the statute, Quinn’s final payment was not

“wrongfully withheld” or subject to the penalty provisions in the PCSPA.

                                            III

                                             4
       Quinn’s contentions that the District Court erred in denying attorneys’ fees,

interest and penalty payments against Dolner under §§ 512 and 507(d) of the PCSPA are

equally unavailing. The District Court found that Dolner complied with the good faith

provisions of § 511, thereby relieving itself of the obligation to comply with the fourteen-

day payment provision set forth in § 507(c). Because payment was withheld in good

faith, it was not wrongfully withheld under § 512(a), and was thus not subject to the

interest and penalty provisions of the PCSPA. See John B. Conomos, Inc., v. Sun Co.,

831 A.2d 696, 711 (2003) (holding that the PCSPA provides for penalties and attorneys’

fees to be ordered “for untimely payment of amounts improperly withheld”) (emphasis

added).

       Quinn’s argument that the District Court erred in not applying the statutory interest

rate set forth in the PCSPA because that rate is not waivable by the parties is incorrect

because the interest provision that Quinn relies on “provides for interest on impermissibly

delayed payments.” Conomos, 831 A.2d at 710 (emphasis added). Thus, the District

Court did not err in determining that the Dolner-Quinn contract incorporated by reference

the interest provision in the Owner-Contractor contract, which states that the prime rate is

the applicable rate of interest on payments due and unpaid. Quinn does not challenge that

finding.

       For the foregoing reasons, we will affirm the judgment of the District Court.

                                              5