Court Opinion

ID: 8261431
Source: CourtListenerOpinion
Date Created: 2022-10-16 15:54:42.059957+00
Date Added: 2024-06-11T16:43:11.739516
License: Public Domain

Biggs, J.
This is the second appeal in this case (55 Mo. App. 427). The reported opinion contains a full statement of all the facts. The action is against the defendants Meehan and Creagan for work done and materials furnished by plaintiff in the construction of some flats belonging to the defendant Dunn. 'Meehan and Creagan had the contract with Dunn for the construction of the buildings, and the plaintiff was a subcontractor under them. The plaintiff also sought to enforce his mechanic’s lien against the buildings. Meehan and Creagan made no defense. Dunn did not dispute the plaintiff’s debt or the regularity of the lien. He set up a counterclaim against the plaintiff as surety on the builders’ bond of Meehán and Creagan. The conditions of the bond were that Meehan and Creagan would fully perform their contract with Dunn. In support of the counterclaim he averred in his answer that the buildings were not completed within the time prescribed in his contract with Meehan and Creagan, and that by its terms he was to be compensated for the delay at the rate of $5 per day, and that the work had been delayed one hundred days.
, The plaintiff in his reply admitted the execution of the bond, and he made no attempt to controvert Dunn’s evidence as to the delay in the completion of the work. In discharge of his liability on the bond he averred that there was a departure from the original plans and specifications, which required the furnishing of other additional materials and labor of the value of $100 in the construction of the buildings; that the architect or superintendent of the buildings directed Meehan and Creagan to make such additions without any agreement or writing as to their cost; that this was in violation of the building contract and that by reason whereof the plaintiff as surety on the bond was discharged.
*216On the first appeal we reversed the judgment for error in the defendant’s instructions. Concerning the alleged additions to the work we decided that if “the change in the depth of the cellar was caused solely by the negligent act of Meehan and Creagan, and the partition fence was built by them without orders from anyone, and the extra work on the bath rooms and the closets was performed after the completion and acceptance of the buildings and under another and independent contract between them and Dunn, then the liability of the plaintiff on the bond was in nowise affected.” On the' retrial of the case the evidence on both sides was directed mainly to these issues. There was a verdict for the plaintiff as to the debt and lien and against Dunn on his counterclaim. Judgment was entered accordingly. Dunn alone has -appealed. He complains of the admission of evidence, the improper remarks of plaintiff’s counsel in his argument to .the jury, and of plaintiff’s instructions.
Instructions. The same alleged vice in plaintiff’s instruction, of whitíh complaint is made, is to be found in one given at the instance of the defendant. The latter is therefore in no position to urge his objection.
As we have concluded that the judgment ought to be reversed by reason of improper remarks by plaintiff’s counsel in the closing. argument to the jury, we need not discuss the assignment as to the evidence, the matter complained of being a mere-accident of the trial.
marks of counsel jury: conflict in The plaintiff’s counsel had the closing argument to the jury. He said: “The court tells you if the extra work was not occasioned by the act of Meehan and Creagan, but was occasioned by the plans, the architect not estimating the proper lay of the land, Mr. Killoren as surety is no longer bound. I am not to stand here *217and make faces at Mr. Dunn and say he is a pawnbroker or any thing else.” Dunn’s counsel objected and excepted to the use of the language. The court said: “There is no evidence of this kind.” Counsel for Dunn said: “I ask the court to rebuke him.” The court took no notice of this request. Counsel for plaintiff continuing his argument, said: “It does not make any difference who the man is, the law is the same. I have not said that Mr. Killoren is a plumber. I have not stood here and said because Mr. Dunn is a sleelc-looking capitalist that you should find this or that. I do not argue cases that way. It is not necessary that I stand here and make grimaces when I argue a case or when the other counsel is arguing the case.”
It is conceded that the intimation that Dunn was a “pawnbroker” and “a capitalist” was not warranted by any evidence in the case. Under the issues no such evidence could possibly have become pertinent. If plaintiff’s counsel, in the examination of witnesses, had propounded a question with the view of eliciting either fact, it would have been the duty of the court not only to interpose and prevent the question from being answered, but also to administer a rebuke to counsel ■ for asking it. As it is, the conduct complained of is far more reprehensible. Plaintiff’s counsel was making the final argument to the jury, and his reference to Dunn as “a pawnbroker” and “a sleek-looking capitalist” very probably had a tendency to create a prejudice against him in the minds of some, if not all, of the jurors. It is well known that there is a general prejudice against pawnbrokers. They are regarded by many people as usurers and extortioners, and in legal contests between them and the ordinary citizen the average juror’s sympathies are always with the latter. Hence the insinuation that Dunn was a pawnbroker and a well fed capitalist, when coupled with the reminder *218that Killoren was a mechanic, undoubtedly had a strong tendency to arouse in the minds of at least some of the jurors a feeling of resentment against Dunn. The high standing of plaintiff’s attorney warrants us in saying that no such result was intended by him. He was engaged in a heated ¿rgument, and had no time or was not in proper condition of mind to weigh his words, but he certainly knew that his statements were outside of the evidence, and he also knew that in pursuing such a course he assumed for his client the risk of having the court decide that his remarks were prejudicial to the other side. Counsel for Dunn pursued the only course open to him, and that was to object and ask that plaintiff’s attorney be rebuked. This the court failed to do. . Its remark that there was no evidence to support the statements did not meet the exigencies of the case. A rebuke should have been administered, and so strongly that the minds of the jurors would have been impressed with the fact that in passing on the issues, it was their sworn duty to put aside such considerations as the statements of counsel suggested.
If we could say that under the, evidence the judgment was for the right party we might affirm it, notwithstanding the improper conduct of plaintiff’s counsel. But there was a sharp and decided conflict in the proof bearing on all of the material issues and therefore we can not say that the jurors were not controlled or influenced by the objectionable statements.
The judgment will be reversed and the cause remanded. It is so ordered.
All the judges concur.