Court Opinion

ID: 4229822
Source: CourtListenerOpinion
Date Created: 2017-12-18 21:07:35.239963+00
Date Added: 2024-06-11T07:47:57.849022
License: Public Domain

IN THE SUPREME COURT OF TI~HE STATE OF DELAWARE

EXELON GENERATION §
ACQUISITIONS, LLC, § No. 28, 2017
§
Defendant Below, § Court Below: Superior Court
Appellant/Cross-Appellee, § of the State of Delaware
§
v. § C.A. No. N13C-07-330
§
DEERE & COMPANY, §
§
Plaintiff Below, §
§

Appellee/CroSs-Appellant.

Subrnitted: October 4, 2017
Decided: December 18, 2017

Before STRINE, Chief Justice; VALIHURA, SEITZ, and TRAYNOR, Justices;
and GLASSCOCK, Vice Chancellor,* constituting the Court en banc.

Upon appeal from the Superior Court. REVERSED.

David J. Margules, Esquire, BALLARD SPAHR LLP, Wilmington, Delaware;
Matthew E. Price, Esquire, (argued), JENNER & BLOCK LLP, Washington, D.C.;
Geoffrey A. Kahn, Esquire, Matthew A. White, Esquire, Of Counsel, BALLARD
SPAHR LLP, Philadelphia, Pennsylvania, Attorneys for Defendant Below,
Appellant/Cross-Appellee.

Peter J. Walsh, Jr., Esquire, (argued), Matthew F. Davis, Esquire, Jacob R. Kirkham,

Esquire, POTTER ANDERSON & CORROON LLP, Wilmington, Delaware,
Attorneysfor Plaz`ntz'j“Below, Appellee/Cross-Appellam‘.

TRAYNOR, Justice:

 

Sitting by designation under Del. Const. art. IV, § 12.

When Exelon Generation Acquisitions purchased Deere & Company’s wind
energy business, it agreed to make earn-out payments to Deere if it reached certain
milestones in the development of three wind farm projects that were underway at the
time of the sale. One of the projects was the Blissfield Wind Project, which was
defined in the parties’ Purchase Agreement as “the wind project under development
in Lenawee County, Michigan, by Blissfield Wind Energy, LLC with a nameplate
capacity of` 81 megawatts.”1 Included in the sale of the Blissfield Wind Project was
a “Power Purchase Agreement”_a binding commitment Deere had secured from a
local utility to purchase energy from the wind farm once it commenced operations.

lt is undisputed that Exelon was unable to bring the Lenawee County site to
fruition because of civic opposition. But shortly thereafter, Exelon managed to
acquire another nascent wind farm from a different developer, this time at a site in
Gratiot County, Michigan, about a hundred miles away from the site of the Blissfield
Wind Project. Exelon managed to persuade the local utility to transfer the Power
Purchase Agreement there, and this time, the wind farm was successful

Deere caught wind of Exelon’s success with the new site (and its use of` the
Power Purchase Agreement) and filed suit to recover the earn-out payment, claiming

that “Exelon had simply relocated the Blissfield Wind Project to Gratiot County”2

 

App. to Opening Br. A302.
Complaint 11 26, No. N13C-07-330 (Del. Super. Ct. July 25, 2013).

N>-¢

and that the earn-out payment obligation had traveled with it. Exelon denied that it
had relocated the project, contending that, after it was prevented from developing
the Blissfield Wind Proj ect by forces beyond its control, it acquired and developed,
at great expense, a new project in Gratiot County with different counterparties,
developers, equipment manufacturers, landowners, townships, counties, and
permits.

On cross-motions for summary judgment, the Superior Court sided with
Deere’s interpretation of the Purchase Agreement and ordered Exelon to pay the $ 14
million earn-out payment for successfully developing a wind farm in Gratiot County.
We disagree with the Superior Court’s interpretation of the Purchase Agreement and

therefore reverse.

l
A

In August of 2010, Exelon agreed to acquire all of the limited liability
company interests of John Deere Renewables, LLC, a wholly owned subsidiary of
Deere & Company that held its wind assets. The base purchase price was $860
million.

One of the subsidiary LLCs that Exelon acquired was Blissfield Wind Energy,
LLC, of which Deere owned a 50% interest, the other 50% being held by a separate

entity called Great Lakes Wind, LLC. At the time of the transaction, Blissfield was

2

developing a wind farm called the Blissfield Wind Project, which the Purchase
Agreement between Exelon and Deere defined as “the wind project under
development in Lenawee County, Michigan, by Blissfield Energy, LLC, with
nameplate capacity of 81 megawatts.”

Just two months before the sale, Deere had succeeded in securing a power
purchase agreement (PPA) for the Blissfield Wind Project with Consumers Energy
Company, an electric utility in Michigan, Under the PPA, which stipulated that the
Blissfield Wind Project would be located in Lenawee County, Michigan, Consumers
agreed to purchase energy generated by the Proj ect for twenty years at a fixed rate
schedule. lt is undisputed that a PPA is a valuable asset that helps to ensure the
viability of a wind farm.

At the time of the sale, Blissfield was one of three wind farms under
development in Michigan for which Deere had secured PPAS, which the Purchase
Agreement collectively referred to as the Michigan Wind Projects. As a condition of
the sale, Exelon agreed that if those three Projects were to achieve certain
development milestones, it Would pay Deere an additional amount, above the base
purchase price, for each Project that achieved the milestones (a so-called earn-out
payment). Whether Exelon owes Deere an earn-out payment for the Blissfield Wind

Proj ect is at the center of this dispute.

B

When the Purchase Agreement was executed, the parties were aware that there
was civic opposition to the development of a wind farm in Lenawee County. And
although Deere represented in the Agreement that it “reasonably believe[d] that all
material Permits necessary for the development, construction, ownership,
maintenance, use and/or operation of the [three] Michigan Wind Projects. . . [could]
be obtained in the ordinary course,”3 one of Deere’s disclosure schedules that Was
attached to the Agreement warned of the possibility of a moratorium on wind energy
projects in Riga Township, the planned location in Lenawee County for the
Blissfield Wind Project.4 In fact, an internal Deere memorandum revealed that

Deere believed that the vice chair of the Riga Township Planning Commission

 

3 App. A336.
4 Under headings that read “Michigan Wind Projects Permits - Blissfield Wind Proj ect,” the
disclosure states:

The Riga Township Planning Commission voted on August 2, 2010 to recommend
to the Riga Township Board a 12-month moratorium on Wind energy projects,
which is scheduled to be considered by the Riga Township Board at its September
13, 2010 meeting The moratorium, as currently proposed, would automatically
expire upon approval of a wind energy Zoning ordinance.

If 15% of the registered voters in a Michigan township sign a petition requesting a
referendum within 30 days after a Zoning ordinance is enacted in such township,
the zoning ordinance would become subject to a referendum vote at the next
scheduled election. Based on the level of resistance to the Blissfield Wind Project
in Ri ga township there is a possibility that a zoning ordinance permitting the project
would be put to a referendum

App. A454.

“[was] actively working with the opponents of the [Blissfield] project to prevent the
wind projects in Riga from becoming a reality.”5 Against this backdrop, Exelon and
Deere executed the Purchase Agreement.

Only eleven months after they signed the Purchase Agreement, Riga
Township passed a zoning ordinance that rendered development of the Blissfield
Wind Project “impossible” from a regulatory perspective6 Consequently, Exelon
provided Consumers Energy with a notice of a force majeure event under the PPA,7

which suspended Exelon’s obligations and jeopardized its chance to use the PPA.

C

After the setback in Lenawee County, Exelon began to devise ways to salvage
the PPA. Within a month of declaring the force majeure event, Exelon informed
Consumers that it was “pursuing several alternatives,”8 including the possibility of
submitting a request to the Riga Township authorities for a new zoning ordinance to

allow the development to go forward, acquiring additional parcels in nearby Ogden

 

App. A287.

App. A719.

The PPA defines “Force Maj eure” as “acts or actions beyond the reasonable control of the
affected Party, including Without limitation, acts of God; flood; earthquake; storm or other natural
calamity; war; insurrection; riot; curtailment (including any curtailment ordered by any Reliability
Authority), order, regulation or restriction imposed by governmental authority; fire or explosion
not caused by criminal acts by the Party claiming Force Majeure; transportation accidents 0r perils
at sea; or other Similar cause beyond the reasonable control but not due to negligence of the Party
affected.” App. A259.

8 App. to Answering Br. B177.

7

Township and constructing a wind farm there, which would have satisfied the PPA’s
requirement that a wind farm be built in Lenawee County, and assessing the
feasibility of “moving the Projec ” to an “alternative site . . . in a nearby county
within Michigan.”9 Exelon ultimately decided to pursue the last of these
alternatives, hopeful that Consumers would be willing to amend the PPA to allow
the wind farm to be built in either Gratiot or Ionia County, rather than Lenawee. To
that end, Exelon sent a draft letter to Consumers stating that, while it could not
proceed with the “Blissfield Wind project . . . at the current Plant Site”10 (i.e.,
Lenawee County), Exelon believed that the PPA could be amended with Consumers’
consent to allow the wind farm to be built in an area in Michigan with a more
favorable political climate for wind development

Consumers was initially reluctant to amend the PPA,ll but eventually agreed,
subject to the necessary regulatory approvals. This modification did not come
without a cost to Exelon: it agreed to reimburse Consumers for tax credits
Consumers might lose if the project were not completed before the credits expired.

This amounted to approximately $16 million in new risk for Exelon, although, as

 

9 App. 13178.

10 App. Bl74.

11 App. A528-29 (containing an email thread among Exelon employees in which one
employee, who spoke with Consumers, reported to the others that while Consumers was “open to
discussion,” it Was “not willing,” at that time, “to say that they support it” in light of Consumers’
concerns that a transfer of the PPA to a “replacement project” would lead to delays and likely
require regulatory approval).

6

will be seen, that risk never came to fruition. In due course, the amended PPA
received regulatory approval.

Around that same time, Exelon purchased a wind farm development known
as the Beebe Wind Farm from another developer, Nordex USA, lnc., for $10.3
million. This development was located in less wind-hostile Gratiot County, about a
hundred miles from Lenawee County, and this time, there was no civic opposition
that prevented Exelon from bringing the wind farm online. With the amendment that
Exelon and Consumers had made to the PPA, the Beebe Wind Farm satisfied the
PPA’s milestones, and Exelon succeeded in getting to use a PPA that seemed all but
lost when development faltered in Lenawee County.

Exelon did continue its efforts to develop a wind farm in other parts of
Lenawee County, but because the other townships were as opposed as Riga to having
a wind farm in their backyards, those efforts were unsuccessful So in May 2012,
citing the restrictive wind energy ordinances passed by officials in Lenawee County,
Exelon notified Deere that it was abandoning the Blissfield Wind Project. Section
2.6(b) of the Purchase Agreement contained a mechanism for Exelon to release itself
from its contractual obligation to continue to develop the Project if further
development were to become commercially infeasible, and Exelon invoked that
mechanism here:

In the event [Exelon] reasonably determines that continuing to proceed
with any one or more of the Michigan Wind Projects would not be

7

commercially reasonable and therefore determines to permanently
cease development of and abandon such Michigan Wind Project(s),
[Exelon] shall so inform [Deere], including the reason therefor and
thereafter [Exelon] shall have no further obligation to [Deere] in
connection with such development . . . .12

II

Deere has never contested Exelon’s assertion that it was not commercially
reasonable to proceed with the development of the Blissfield Wind Project in
Lenawee County. Instead, Deere contends that, despite the notice of abandonment,
Exelon did not actually abandon the Project_it merely relocated it to the Beebe
Wind Farm in Gratiot County and satisfied the earn-out-triggering milestones there.
Although Deere admits that the Purchase Agreement describes the Blissfield Wind
Project as the “wind project under development in Lenawee County” and that the
parties, “at the time of negotiating and executing the agreement[,] intended the
Blissfield Wind Project to be developed in Lenawee County and did not anticipate
. . . that it would be moved,” Deere contends that there is “nothing in the Purchase
Agreement that prevented the Blissfield Wind Project from being moved outside of
Lenawee County.”13

In Exelon’s View, the Blissfield Wind Project Was not moveable_it was a

wind farm development in Lenawee County that Exelon reasonably abandoned in

 

12 App. A319.
13 Compl. 11 45.

favor of another development In other words, the Blissfield Wind Project was, as
the Purchase Agreement says, “the wind project under development in Lenawee
County, Michigan,” and whether the Beebe Wind Farm achieved the Purchase
Agreement’s development milestones is of no consequence because it is not that

same wind proj ect.

Ill
A

“The proper construction of any contract . . . is purely a question of law,”14
so we review questions of contract interpretation de novo.15 Our objective is to
determine the intent of the parties from the language of the contract.16 This inquiry
should focus on the parties’ shared expectations at the time they contracted,17 but
because Delaware adheres to an objective theory of contracts, the “contract’s
construction should be that which would be understood by an objective, reasonable

third party.”18 If a contract is unambiguous, extrinsic evidence may not be used to

 

14 Rhone-Poulenc Basic Chems. Co. v. Am. Motorz`sts Ins. Co., 616 A.2d 1192, 1195 (Del.
1992).

15 Eagle Indusmes, Inc. v. De Vilbiss Heal¢h Care, Inc., 702 A.2d 1228, 1231 (Del. 1997).

16 Twm Cizy Fire lns. Co. v_ Del. Racing Ass ’n, 840 A.2d 624, 628 (Del. 2003).

17 See Eagle Industries, 702 A.2d at 1233 n.11 (recognizing that the parties’ intent must be
gauged “at the time they entered into the conlract”).

18 Salamone v. Gordon, 106 A.3d 354, 367-68 (Del. 2014) (quoting Osborn ex. rel. Osborn
v. Kemp, 991 A.2d 1153, 1159 (Del. 2010)).

9

interpret the intent of the parties, to vary the terms of the contract, or to create an

ambiguity.”19

B

We begin with the Purchase Agreement’s plain language Exelon’s obligation
to pay Deere an earn-out for the Blissfield Wind Project was contingent upon “the
Blissfield Wind Project achiev[ing] Completion of Development and
Commencement of Construction.” The “Blissfield Wind Project” is defined by the
Agreement to mean “the wind project under development in Lenawee County,
Michigan, by Blissfield Wind Energy, LLC, with a nameplate capacity of 81
megawatts.” Together, then, payment of the earn-out was contingent upon “the wind
project under development in Lenawee County, Michigan,” achieving “Completion
of Development and Commencement of Construction.”

On its face that presents a problem for Deere, because there is no dispute that
the wind project in Lenawee County neither completed development nor
commenced construction-civic opposition saw to that, But Deere believes the key
lies in the definition of the term “Completion of Development and Commencement
of Construction.” Under the Agreement, a “Completion of Development and

Commencement of Construction” could be triggered in one of two ways. The first is

 

19 Eagle Ina'ustries, 702 A.2d at 1232.
10

the achievement of five development milestones that are spelled out in the
Agreement.20 The second is the reaching of a “Commercial Operation Date.” lt is
this second trigger that forms the basis of Deere’s argument

“Commercial Operation Date” is yet another defined terrn-the Agreement
explains that this term “has, with respect to any Michigan Wind Project, the meaning
set forth in the Michigan PPA related to such Michigan Wind Project.” Exelon
purchased three “Michigan Wind Proj ects” from Deere, the Blissfield Wind Project
being one of them, so to find the meaning of “Commercial Operation Date” as it
applies to the Blissfield Wind Project, the Agreement directs us to the “meaning set
forth in the Michigan PPA related to” the Blissfield Wind Proj ect. “Michigan PPA,”
too, is a defined term, and it refers to three different contracts, one of which is “that
certain Renewable Energy Purchase Agreement, dated as of June 21, 2010 (as
amended, restated, modified, superseded or supplemented from time to time),
between Consumers Energy Company and Blissfield Wind Energy, LLC.” That is
the PPA that, at least as of the date of the sale, related to the wind project under

development in Lenawee County. And sure enough, the PPA contains the term

 

20 Those five milestones are (l) securing relevant permits, (2) securing turbine supply

agreements, (3) securing interconnection agreements, (4) having a Power Purchase Agreement in
place, and (5) commencement of on-site construction of roads and foundations and completion of
initial wind turbine construction

ll

“Commercial Operation Date,” and it refers to the date on which a number of
development milestones listed in the PPA are met.

Exelon, as mentioned, was able to persuade Consumers Energy to transfer
the PPA to the Beebe Wind Farm once the Lenawee County site proved politically
infeasible. To do so required an amendment to the PPA because the PPA made
Various references to the term “Plant Site,” which the PPA had defined as “[t]he site
upon which the Plant will be located in Lenawee County, Michigan.”21 So the two
sides amended that definition to strike “Lenawee County” and replace it with “Ionia
or Gratiot County”_the latter of which being where the Beebe Wind Farm was
under development And there is no dispute that Exelon ultimately succeeded in
achieving a “Commercial Operation Date” at the Beebe Site, as that term is defined
in the PPA, by reaching the milestones listed in the PPA.

The crux of Deere’s argument_which the Superior Court accepted_is that
the achievement of a Commercial Operation Date under the amended PPA
automatically triggered the earn-out payment under the Purchase Agreement. To be
sure, this argument has some superficial appeal. The Purchase Agreement states that
the earn-out is triggered upon the “Completion of Development and Commencement
of Construction,” and one way that could occur is by the achievement of a

Commercial Operation Date, as it is defined under the PPA. So, the argument goes,

 

21 App. A239.
12

the achievement of a Commercial Operation Date under the amended version of the
PPA must have triggered the earn-out under the Purchase Agreement.

But Deere’s argument glosses over textual difficulties that arise when the
interlocking terms in the earn-out provision are read together. As explained, the eam-
out payment was contingent upon “the Blissfield Wind Proj ect achiev[ing]
Completion of Development and Commencement of Construction.” Fully unpacked,
that means that payment was contingent upon “the wind project under development
in Lenawee County, Michigan achiev[ing]” either the five milestones specified in
the Purchase Agreement or the milestones “set forth in the Michigan PPA related to

. [‘the wind project under development in Lenawee, County, Michigan’].”
Although it is true that the milestones set forth in the PPA were achieved, at the time
they Were achieved the PPA was no longer “related to . . . [‘the wind project under
development in Lenawee County, Michigan’]”_it had been amended to relate to the
Beebe Wind Farm. And even if the PPA, post-amendment, still “related to” the
Lenawee County project by virtue of the fact that it was the same agreement that, at
one time, had related to that development, the earn-out was due only if “the wind
project under development in Lenawee County, Michigan, achiev[ed]” the
milestones in the PPA. But it was not that wind project that achieved the

milestones_it was the Beebe Wind Farm, in Gratiot County.

13

IV

Deere’s answer to this interpretive problem is that the Purchase Agreement’s
description of the Blissfield Wind Project as the “wind project under development
in Lenawee County, Michigan,” was not intended to give the term “wind project” a
geographic component-it was just an easy way to distinguish that project at the
time of the sale from the numerous other wind projects that Exelon purchased from
Deere. So to Deere, it is not incongruous to say that when the Beebe Wind Farm, in
Gratiot County, achieved a Commercial Operation Date, that meant, in the language
of the Purchase Agreement, that “the wind project under development in Lenawee
County, Michigan,” achieved Completion of Development and Commencement of
Construction.” The Beebe Wind F arm was still the same “wind project”_it had just
been moved from Lenawee County to the Beebe site in Gratiot County.

But even granting Deere the argument that the phrase “under development in
Lenawee County” was intended only to identify the “wind project”_not define it_
the question still remains whether the Beebe Wind Farm could, in the meaning of
the Purchase Agreement, be the same “wind proj ect” that was once under
development in Lenawee County, and for which Exelon agreed to assume an eam-

out obligation.

14

A

There is no dispute that the PPA is the only common thread between the wind
farm that was under development in Lenawee County and the Beebe Wind F arm that
Exelon acquired from Nordex.22 Deere’s argument, then, would collapse the “wind
proj ect” into nothing more than an idea for a wind farm and a single intangible asset,
untethered in any way to the development that had already begun in Lenawee
County. But a number of provisions in the Purchase Agreement belie the notion that
the parties intended for the “wind project” to have so fluid a meaning that Exelon’s
earn-out obligation could be triggered by its re-use of a single intangible asset from
the Lenawee County development at a wholly separate wind farm_even an
intangible asset as valuable as a PPA.

Most telling are the representations that Deere made to Exelon about the status
of the development at the time of the sale. Deere represented that Blissfield Wind
Energy, the Deere subsidiary that was developing the project, was “targeting the
acquisition of real property interests” that, “together with the real property interests
already held” by the company, “would . . . constitute all of the real property interests

necessary to develop, construct, own, operate, maintain and use the Blissfield Wind

 

22 Deere points out that there is one other connection: Exelon acquired the Beebe Wind Farm

from Nordex through the same legal entity_Blissfield Wind Energy, LLC_that Exelon
purchased an interest in from Deere and that had been developing the wind farm in Lenawee
County. But whatever the “wind proj ect” is, Blissfield Wind Energy is not part of it_it owns it.

15

Project.”23 A map in one of the schedules to the Purchase Agreement shows the
locations of plots of land in Lenawee County that were already under lease at the
time of the sale, as Well as the proposed locations for approximately forty-five wind
turbines.24 The map reveals that Blissfield had already leased land for more than half
of the turbines and was targeting the land needed for another third of them.

Deere also represented that it was “continuing to obtain the Permits necessary
to develop, construct, own, maintain, use and operate” the Blissfield Wind Project
and that it “reasonably believe [d] that all material Perrnits . . . [could] be obtained in
the ordinary course’725 (with the cautionary note that “resistance to the Blissfield
Wind Project in [the] township” could “possibly” lead to a restrictive ordinance26).

So whatever the precise contours of this “wind proj ec ” that Exelon acquired,
we can safely say that it was more than just an idea for a wind farm and a PPA
looking for a home. The project already had a real-property footprint in Lenawee
County, and Exelon had in hand the twin representations from Deere that “no
material impediment exist[ed] to obtaining the [remaining] real property interests”
and that there was a path (so it seemed at the time) toward obtaining the permits for

the wind farm to operate in Lenawee County.27

 

23 App. A335_36.
24 App. A453.
25 App. A336.
26 App. A454.
21 App. A336.

16

B

The representations that Deere made about the suitability of the Lenawee
County site do more than just demonstrate that the “wind project” had a geographic
anchor at the time of the sale_these representations were essential to Exelon’s
willingness to assume the earn-out obligation

At the time of the sale, Deere’S wind energy business included over a dozen
wind projects that were under development, but Exelon agreed to make earn-out
payments for only three of them: the three Michigan Wind Proj ects. And those three
projects are the only projects for which Deere made representations that the real
property and permits necessary for development to succeed at the sites Deere had
chosen for each Proj ect were either already secured or attainable.

That was no coincidence When a buyer like Exelon agrees in advance to make
an earn-out payment for a fixed dollar amount, the buyer needs to assure itself that
the amount it Will have to expend to achieve the earn-out-triggering conditions will
not rise to the point that the earn-out payment will end up out of proportion with the
project’s value. For a project like a wind-farm development, two obvious areas
where costs could spiral are the acquisition of the land necessary to complete the
development and the securing of the necessary approvals from government
authorities Unexpected impediments on either of those f`ronts-like holdout

landowners or stubborn municipalities-could quickly escalate the cost of bringing

17

the wind farm to fruition, eroding the project’s profitability and distorting the
relationship between the value of the project and the fixed earn-out payment

So it is unsurprising that in exchange for the Exelon’s willingness to agree in
advance to a $14 million earn-out payment for the successful development of the
Blissfield Wind Project_before knowing how much it would cost to get there-
Exelon would insist on some assurances about the suitability of the site Deere had
chosen. And Deere obliged by representing that, to its knowledge, there was “no
material impediment . . . to obtaining the [remaining] real property interests” at the
Lenawee County site and that “all material Permits necessary for the developmen ”
of the project at that site could “be obtained in the ordinary course.”28 Those
representations gave Exelon some comfort that Deere Was not trying to offload a
wind development at serious risk for cost overruns in exchange for a fixed payout
that was out of line with the development’s value.

But to accept Deere’s interpretation, we would have to believe that after
securing those representations about the Lenawee County site, Exelon was
nonetheless willing to commit itself to paying the earn-out if it were able to bring a
wind farm to operation anywhere, as long as it made use of the PPA. And that would
upend the Purchase Agreement’s balance between the fixed earn-out payment that

Deere demanded, and Deere’s assurances that it knew of no material obstacles in the

 

22 App. A336.
18

way of land or permit acquisitions at the Lenawee County site that could swell
development costs and swing the proj ect’s value out of line with the amount of the

earn-out.

C

Together, these provisions in the Purchase Agreement make implausible the
notion that a different wind farm, situated in a different location and regulatory
environment (and acquired from another company, no less), was the same “wind
project” that had been under development in Lenawee County, simply because
Exelon was able to persuade Consumers Energy to transfer the PPA there. And aside
from the PPA being the only link between the two developments, that link was
attenuated by Consumers’ demand that, in exchange for transferring the PPA to the
Beebe Wind Farm, Exelon assume the risk that Consumers could lose its tax credits
if the development were not completed in time.

When Exelon first approached Consumers with the idea of amending the PPA
to move it to a new development, Consumers resisted, telling Exelon that if it was
unable to complete development in Lenawee County, then Consumers preferred “to
go out for a rebid.”29 Although Consumers did not foreclose the idea of transferring

the PPA to a new project, it emphasized that its highest priority was that “the

 

29 App. A528.
19

replacement project . . . be built in 2012.”30 Missing the 2012 completion date would
put an estimated $16 million in tax credits that Consumers was set to receive at
risk_a risk that Consumers had to bear under the terms of the PPA as Consumers
and Deere had negotiated them. To secure Consumers’ consent to move the PPA to
the Beebe Wind Farm, Exelon agreed to take on this risk.31

So while Exelon succeeded in finding a way to save the PPA after community
opposition doomed the Lenawee County development, the PPA ended up being on
different terms than Deere had negotiated before the sale, and that further reduces

the little the two developments have in common.

D

The Superior Court offered two reasons why the “wind project” that Exelon
purchased from Deere could be_and was_moved to the Beebe Wind Farrn.

The first turned on the amendment the parties made to the PPA to strike the
reference to “Lenawee County” and replace it with “Ionia or Gratiot County.” In the
Superior Court’s view, that “amendment . . . reflect[ed] the ability of Exelon to

change the project location.”32

 

30 App. A529.
31 As the Beebe Wind Proj ect was in fact completed in 2012, the risk did not materialize, but
that does not mean that Exelon’s assumption of this risk did not work a material change to the

terms of the PPA as they stood when Exelon acquired Deere’s rights to it.
32 2016 WL 3546921, at *5 (Del. Super. Ct. June 2, 2016).

20

But that reasoning_that Exelon’s success in amending the PPA showed that
Exelon could move the wind project-~begs the very question that must be answered:
is amending the PPA tantamount to moving the project? All that the amendment of
the PPA established was that the PPA could be used for a different development It
does not automatically follow that using the PPA for a different development meant
that Exelon had also moved the “wind project,” as that term is used in the Purchase
Agreement, or, more to the point, that the wind project consisted of just an idea for
a Wind farm and the PPA, which both could be freely moved to another site with a
simple amendment to the PPA.

The Superior Court was of the view that the Purchase Agreement’s concept
of the “wind project” had to travel with the PPA because the Purchase Agreement
incorporates the milestones from the PPA as one of the two triggers for the eam-out
payment So if the “wind project” in the Purchase Agreement were not harmonized
with the project in the PPA, the “Purchase Agreement [could not] be given its full

meaning.”33 But that is not so.

 

33 See id. In the course of its discussion, the Superior Court opined that “[t]he Blissfield PPA
is incorporated by reference into the purchase agreement.” Id. Not just the term “Commercial
Operation Date,” which the Purchase Agreement does expressly incorporate, but the entire PPA.
Why the Superior Court needed to reach that conclusion we cannot say, because the only part of
the PPA that the Superior Court found relevant_the amendment the parties made to the term
“Plant Site” by changing “Lenawee County” to “Ionia or Gratiot County”_is incorporated into
the PPA’s definition of “Commercial Operation Date” (through a sort of roundabout reference to
the term “Plant,” which in turn references the term “Plant Site”). So there was no need to
contemplate whether the Purchase Agreement incorporated any other parts of the PPA, or the rest
of it entirely. And to the extent the Superior Court believed that the incorporation of a discrete

21

As explained, the Purchase Agreement provides that the earn-out would be
triggered if “the Blissfield Wind Project achieves Completion of Development and
Commencement of Construction,” which, with its defined terms fully expanded,
means that the payment would be due if “the wind project under development in
Lenawee County, Michigan achieves” either the five milestones specified in the
Purchase Agreement or the milestones “set forth in the Michigan PPA related to . . .
[‘the wind project under development in Lenawee, County, Michigan’].” If the PPA
were transferred to a different wind farm development separating the PPA from the
development in Lenawee County, that would not create an interpretive disconnect
between the Purchase Agreement and its incorporation of the PPA’s milestones_it
would simply mean that “the wind project under development in Lenawee County”

would not be able to achieve those milestones.34

 

term or two from another contract necessarily means that the entire contract has been incorporated,
we disagree See 11 Richard A. Lord, Williston on Contracts § 30:25, at 234, 238 (4th ed. 1999)
(“It is not necessary to refer to or incorporate the entire document; if the parties so desire, they
may incorporate a portion of the document . . . While discussion of incorporation by reference is
often framed in terms which suggest the complete absorption of one document into another, it is
important to note that when incorporated matter is referred to for a specific purpose only, it
becomes a part of the contract for that purpose only, and should be treated as irrelevant for all other
purposes.”).

34 Our understanding that a transfer of the PPA to a different wind farm development would
end any chance that Blissfield Wind Project could meet the PPA’s milestones, which constitute
one of the two triggers for the earn-out, does not leave the Purchase Agreement vulnerable to earn-
out-avoiding gamesmanship. The Purchase Agreement required Exelon to “us[e] all commercially
reasonable efforts and Prudent Industry Practices to . . . complete development and commence
construction” on Blissfield Wind Project “such that [the Project] would . . . achieve commercial
operation by the . . . Commercial Operation Milestone Date” in the PPA, App. A319, so only in
scenarios such as this one, where some unexpected occurrence (like a hostile municipality)
rendered it commercially unreasonable to continue development at the Lenawee County site, could

22

The second reason the Superior Court offered was its view that Exelon’s
“actions and representations at the time it was seeking to amend the Blissfield PPA”
showed that Exelon itself believed that the “wind project” was something it could
move to another site. Among the evidence the court seized upon was the force
majeure letter that Exelon sent to Consumers Energy shortly after the restrictive
ordinance was passed in Riga Township, in which Exelon told Consumers that “[t]he
Force Majeure event [would] continue unless and until these new regulations are
repealed . . . or the Project is moved to an alternate location.”35 Exelon spoke in
similar terms to Consumers in a second letter sent shortly thereafter, in which it told
Consumers that it “ha[d] identified a possible alternative site for the Project in a
nearby county within Michigan and is currently assessing the feasibility of moving
the Proj ect to this location.”36 But, of course, these letters do not mean that the Beebe
Wind F arm was “the wind project under development in Lenawee County,
Michigan” for purposes of the Purchase Agreement, to which Consumers was not a
party. They simply recognize that Exelon was hopeful it could identify a substitute
site that_with Consumers’ consent-could fulfill the role that the Blissfield Wind

Project was supposed to play, but could not, under the PPA. And Exelon also

 

Exelon have moved the PPA and abandoned the Lenawee County development And the notion
that Exelon might be trying to game the earn-out provision is undermined by the fact that it
willingly paid Deere earn-out payments for its successful development of the other two Michigan
Wind Proj ects.

35 App. A531 (emphasis added).

36 App. B178 (emphasis added).

23

apparently included a line item for the $14 million earn-out payment to Deere in one
of its internal valuations of the Beebe Wind Farm, which the Superior Court
interpreted as suggesting that Exelon_or at least someone in its finance
department_believed that the “wind proj ect” Was moveable. But this document may
simply reflect that there was a risk Deere would argue that the Beebe Wind Farm
counted, Which Exelon believed was prudent to factor into its decision making37

The questionable value of these documents aside, what is important is that
they are all parol evidence Extrinsic evidence like this cannot be used “to interpret
the intent of the parties” or “to vary the terms of the contract” unless the contract
suffers from some ambiguity.38 But the Superior Court concluded-and we agree_
that “[t]he Purchase Agreement is unambiguous in its terms relevant to this case.”39
So why the parol evidence? The Superior Court believed that when a contract
contains an earn-out provision, a court is allowed to consult “post-closing events and
circumstances” to “resolve the parties’ rights and obligations under the contract.”4°
That was error.

The Superior Court said that when a dispute arises over a party’s entitlement

to a contractual earn-out payment, “it [is] necessary for the [court] to examine the

 

37 See also App. A530 (Deere internal email confirming Deere’s intent to write off the earn-

out connected to the Blissfield Wind Project).
38 Eagle Industries, 702 A.2d at 1232.

22 2016 WL 3546921, at *6.

40 See id

24

post-closing conduct of the parties” to “deterrnine whether the seller [is] entitled to
the earn-out.”41 That is true enough. But it stands for nothing more than the obvious:
when a party to a contract claims that the other breached (such as by failing to pay
an earn-out that was allegedly due), whether a breach has occurred depends upon
what the parties did (or did not do) after the contract was formed. That evidence
cannot be used, as the Superior Court did here, as an aid to interpreting the meaning
of the contract So although the parties’ post-closing conduct is essential to
determining whether the Beebe Wind Farm met the Purchase Agreement’s definition
of the “wind project under development in Lenawee County, Michigan,” and, if so,
whether the Beebe Wind Farm achieved the earn-out triggering milestones, it
cannot_absent an ambiguity that the Superior Court did not identify-be used to
determine what the parties meant by “the wind farm under development in Lenawee
County, Michigan,” and whether they understood it to be tethered to Lenawee

County.

 

41 ld
25

V
For the foregoing reasons, the Superior Court’s grant of` summary judgment
in favor of Deere is reversed, and this case is remanded with instructions to enter

judgment in favor of Exelon.42

 

42 In light of our conclusion that Exelon does not owe the earn-out payment, We need not

address the Superior Court’s rejection of the affirmative defenses that Exelon raised in the hopes
of defraying some or all of that payment

26