Court Opinion

ID: 2655035
Source: CourtListenerOpinion
Date Created: 2014-02-27 19:38:52.21977+00
Date Added: 2024-06-11T12:18:06.438210
License: Public Domain

Filed 2/27/14 City of Novato v. Morgan CA1/3
                      NOT TO BE PUBLISHED IN OFFICIAL REPORTS
California Rules of Court, rule 8.1115(a), prohibits courts and parties from citing or relying on opinions not certified for
publication or ordered published, except as specified by rule 8.1115(b). This opinion has not been certified for publication
or ordered published for purposes of rule 8.1115.

              IN THE COURT OF APPEAL OF THE STATE OF CALIFORNIA

                                       FIRST APPELLATE DISTRICT

                                                DIVISION THREE

CITY OF NOVATO,
         Plaintiff and Appellant,
                                                                     A130899
v.
DANIEL H. MORGAN et al.,                                             (Marin County
                                                                     Super. Ct. No. 060409)
         Defendants and Respondents.

         This appeal concerns the scope of a personal guaranty to perform obligations
under agreements to develop a residential subdivision. The transaction at issue involved
three Subdivision Improvement Agreements (SIA’s), which we refer to as SIA 1, SIA 2,
and SIA 3. In prior litigation involving SIA 1 and SIA 2, plaintiff and appellant City of
Novato (city) was successful in actions against the subdivision developers and received
awards of attorney fees. Now, in light of the developers’ apparent inability to satisfy the
attorney fee awards, the city seeks to enforce a personal guaranty and require the
guarantors to pay the entire amount of fees previously assessed.
         It is undisputed that the individual defendants, respondents Daniel H. Morgan and
Mark Cunningham (collectively, defendants), personally guaranteed the performance of
obligations owed under SIA 2. The dispute is over whether the personal guaranty
extends to SIA 1. The trial court concluded that defendants’ guaranty extended only to
obligations owed under SIA 2, and it further concluded that the city had not satisfied its
burden to show that defendants breached the guaranty as to SIA 2, in effect relieving

                                                             1
defendants of any obligation to pay attorney fees awarded to the city in the prior
litigation. The court also awarded attorney fees to defendants in this litigation.
       We agree with the trial court that the scope of the guaranty does not extend to
SIA 1, and that defendants are not liable for attorney fees attributable to enforcing SIA 1.
However, we conclude that defendants are liable under the guaranty for that portion of
the attorney fee awards attributable to enforcing SIA 2. Because the trial court did not
reach this issue in resolving the city’s cause of action for declaratory relief, we shall
reverse and remand to the trial court for a determination as to the amount of the fees
awarded in prior litigation that defendants are obligated to pay as a consequence of their
guaranty. We also reverse the attorney fees awarded in this litigation in light of our
disposition.
                       FACTUAL AND PROCEDURAL BACKGROUND
                       The Agreements to Develop the Subdivision
       The subdivision at issue in this case is known as Marin Country Club Estates –
Unit 3 (subdivision) and includes 54 acres of land. In 1997, defendant Morgan
approached the city about developing the subdivision. Morgan, a developer, was also
president of Centennial Homes Inc. (Centennial), which acted as a general contractor for
subdivisions built by Morgan and his related businesses. Morgan represented to the city
that he would fix drainage problems on the subdivision property, develop seven lots on
nine acres, and convey the 45-acre balance of the property to the Marin County Open
Space District (Open Space District) to be preserved as open space.
       Centennial, Morgan, and defendant Mark Cunningham created MCCE
Development, LLC (MCCE Development) and MCCE Investors, LLC (MCCE Investors)
to take title to the subdivision property and undertake development. Except where
necessary to distinguish between the two MCCE entities, we shall refer to them
collectively as MCCE.
       The city attorney, Jeffrey Walter, sent Morgan a single proposed Subdivision
Improvement Agreement, or SIA, covering the entire project. However, Morgan
proposed that the project be broken into three separate agreements for tax purposes. The

                                              2
city accommodated Morgan’s request and memorialized the transaction in three
documents that we refer to as SIA 1, SIA 2, and SIA 3.
       SIA 1 obligated MCCE Development to construct all improvements needed to
support the development of lots 1 to 7 of the subdivision. In addition, MCCE
Development was required to repair and restore a nearby creek that runs through the
subdivision.
       SIA 2 gave MCCE Investors the option to complete improvements necessary to
develop lots 8 through 37. In the alternative, MCCE Investors could elect to donate the
lots to an organization dedicated to the preservation of open space. From the beginning,
it was always the intent of MCCE Investors to donate lots 8 through 37 in order to
preserve the land as open space and receive a tax benefit.
       SIA 3 concerned the dedication of land for a park but only came into effect if lots
8 through 37 were developed. SIA 3 is not at issue in this litigation.
       The SIA’s were the subject of negotiations between Walter, on behalf of the city,
and Judy Davidoff, an attorney representing Morgan and MCCE. Each of the SIA’s
contains what the city describes as a cross-default and cross-remedy provision (hereafter
referred to as a “cross-default provision”) providing that a breach of one SIA constitutes a
breach of the others, with all of the remedies under one SIA available for a breach of any
of the other SIA’s. Walter insisted upon including the cross-default provision in each
SIA in order to ensure that breaking the SIA into three agreements would not prevent the
city from enforcing each SIA or accessing the security posted for each of the SIA’s.
Walter was particularly concerned that, without some provision tying the SIA’s together,
MCCE might develop the homes under SIA 1 but allow its obligations concerning the
preservation of open space under SIA 2 to languish. Walter explained the cross-default
provision to Davidoff, who agreed to include the provision in each of the SIA’s.
       The cross-default provision in SIA 2, which is similar to the cross-default
provisions in the other SIA’s, provides: “[MCCE’s] breach of or default under SIA #1
and/or SIA #3 shall be deemed a breach of or default under this Agreement, and the City

                                             3
shall have all the remedies available under this Agreement for such defaults and/or
breaches of SIA #1 and/or SIA #3.”
       Each of the SIA’s contains an attorney fees and cost provision that provides as
follows: “In the event either party hereto commences any legal action or proceeding
against the other party arising out of or in connection with this Agreement, the party
prevailing in said action or proceeding shall be entitled to recover, in addition to its costs
of suit, reasonable attorneys’ fees to be fixed by the court, and such recovery shall
include costs of suit and attorneys’ fees on appeal, if any.”
       A paragraph in the recitals of each SIA refers to obligations owed under the other
SIA’s. The pertinent recital in SIA 2 reads: “WHEREAS, the parties hereto are also
executing those certain subdivision improvement agreement[s] of even date herewith (the
‘SIA #1’ and ‘SIA #3’), which SIA #1 and SIA #3 provide an alternative or supplemental
performance by Subdivider for completion of the necessary improvements for the
Subdivision . . . .” The parties agreed to include a contractual provision in each of the
SIA’s that provides as follows: “The recitals are part of this Agreement and are hereby
incorporated by this reference.” In its briefing on appeal, the city refers to this provision
as the “incorporation paragraph.” At trial, Walter articulated his view that, by expressly
incorporating the recitals into each SIA through the incorporation paragraph, MCCE was
acknowledging that it was agreeing to perform the obligations under the other SIA’s.
                   Negotiations Resulting in the Guaranty Agreement
       When the SIA’s were originally being negotiated, Walter included in the draft
agreements a guaranty provision requiring the principals and members of MCCE to
execute a personal guaranty ensuring performance of the SIA’s. Walter sought a personal
guaranty because the city was concerned about the risks of relying on “one asset” limited
liability companies if the city encountered problems in trying to enforce the SIA’s.
       Davidoff rejected the idea of a personal guaranty on behalf of defendants.
According to Walter, he was not concerned that defendants refused to provide a personal
guaranty because it is customary for surety bonds to be used as security for performance
of SIA’s. Accordingly, the city was willing to accept surety bonds as security in lieu of a

                                              4
personal guaranty. Thus, when the parties executed the final SIA’s, the agreements did
not contain a requirement of a personal guaranty.
       Shortly after the city approved the SIA’s, MCCE learned it could not obtain bonds
for SIA 2 and SIA 3. Davidoff explained to Walter that MCCE could not obtain bonds to
secure performance of SIA 2 and SIA 3 because the nature of the obligations under those
agreements was uncertain. However, MCCE was able to obtain a surety bond for SIA 1.1
The inability to obtain bonds for SIA 2 and SIA 3 was problematic because the city
required security for each SIA as part of its regular practice and to comply with the
Subdivision Map Act.
       Davidoff contacted Walter to address the need for security. She affirmed that a
bond would be obtained for SIA 1 and offered deeds of trust against lots 8 through 37 to
secure performance of SIA 2 and SIA 3. On behalf of the city, Walter required Morgan
and Cunningham to execute a personal guaranty in addition to offering deeds of trust.
Walter explained at trial that “as a result of . . . not being able to find bonds for [SIA] 2
and 3, the parties moved forward in trying to find some security device that would take
care [of SIA] 2 and [SIA] 3 . . . .” In other words, the parties saw no need to find
alternative security for SIA 1, as to which MCCE was able to secure a surety bond.
       One of the early drafts of a guaranty agreement offered by Walter was a “blanket
guarant[y]” covering all three of the SIA’s. When presented with the draft, Morgan
refused to guarantee SIA 1 and directed his attorney, Davidoff to convey his refusal to
Walter. In subsequent drafts of the guaranty, it was expressly limited to SIA 2 and SIA 3.

       1
         As defendants acknowledge, the surety bond does not expressly identify SIA 1,
although it plainly applies to SIA 1 because the amount of the bond corresponds to the
cost of the improvements required under SIA 1. The city concedes on appeal that “the
amount of the bond is consistent with the amount related to improvements for SIA 1,”
and it states in its brief that MCCE could only obtain a bond for SIA 1 but not SIA 2 or
SIA 3. Walter likewise testified at trial that MCCE was not able to find bonds for SIA 2
and SIA 3.

                                               5
       At trial, Walter confirmed that Davidoff “did not want to include [SIA] 1” in the
guaranty. Accordingly, as the city acknowledges in its brief on appeal, the draft guaranty
was modified so that it was expressly limited to SIA 2 and SIA 3.
       In December 1999, defendants Morgan and Cunningham executed the guaranty
agreement (hereafter “guaranty agreement” or “guaranty”) that is the primary focus of
this appeal. The guaranty agreement provides in relevant part that defendants “hereby
unconditionally guarantee to the City of Novato, a municipal corporation . . . the full and
timely performance of each and every one of the obligations of [MCCE] . . . as the
subdivider under and as specified in those certain Subdivision Improvement Agreements
Numbers 2 and 3 by and between the City and Obligor and dated July 13, 1999 and the
Deeds of Trust with Assignment of Rents of even date securing said Subdivision
Improvement Agreements . . . .” (Italics added.) Under the guaranty agreement,
defendants waived any right to require the city to proceed first against MCCE before
proceeding against defendants to compel performance under SIA 2 and SIA 3. The
guaranty agreement contains an attorney fees clause directing defendants to pay the city’s
legal expenses incurred in connection with enforcement of the guaranty.
       The final, executed guaranty agreement contains no reference to SIA 1. Walter
testified that he and Davidoff never discussed the guaranty’s application to SIA 1.
Walter explained at trial that he did not insist on including a specific reference to SIA 1
in the guaranty agreement because he believed that by substituting the personal guaranty
for surety bonds on SIA 2 and SIA 3, the guaranty would be available as a remedy for
any breach of SIA 1 under the cross-default provision previously included in each of the
SIA’s. However, Walter conceded at trial that he did not specifically convey his belief to
Davidoff at the time they were negotiating the guaranty agreement.
                  MCCE’s Failure to Perform Under SIA 1 and SIA 2
       Following the execution of the SIA’s, MCCE developed and sold three homes. In
December 2002, the city passed a resolution finding MCCE in default of SIA 1 as a result
of its failure to complete required subdivision improvements, including creek restoration
work. Walter sent a letter to MCCE on behalf of the city giving notice that it was in

                                              6
breach of SIA 1 and was in default under SIA 2 pursuant to the cross-default provisions
of the SIA’s.
       After MCCE failed to make progress in transferring lots 8 through 37 to the Open
Space District pursuant to SIA 2, the parties entered into a First Amendment to SIA 2 that
required MCCE, among other obligations, to transfer lots 8 through 37 under an
Irrevocable Transfer Agreement and to complete the transfer no later than one year after
March 18, 2002.
       In September 2009, defendants caused MCCE to deliver to the Open Space
District proposed deeds and conservation easements relating to lots 8 through 37. The
Open Space District agreed to accept the deeds in April 2010, although escrow still could
not close because MCCE owed back taxes on lots 8 through 37. Additionally, a deed
granting an easement over lot 7 was incorrect because it was executed by a prior owner
and not by MCCE, which was the owner of lot 7 at the time the Open Space District
accepted the transfer documents in April 2010. According to the city, neither of these
hurdles to completing the transfer—the payment of back taxes and the correction of the
easement—was accomplished before the trial on the guaranty.
                             Prior Litigation Involving MCCE
       MCCE filed suit against the city in September 2002 alleging breach of contract.
To distinguish the earlier litigation initiated by MCCE from the action that is the subject
of this appeal, we refer to the earlier lawsuit as the “MCCE action” and the lawsuit giving
rise to this appeal as the “guaranty action.”
       In the MCCE action, the city filed a cross-complaint against MCCE as well as
against Morgan and Cunningham, alleging a breach of SIA 1 and SIA 2. After the
MCCE action had been initiated, MCCE transferred lots 4 through 7 of the subdivision to
George Morf. The city thereafter amended its cross-complaint to include Morf and
Centennial, the general contractor, as cross-defendants. MCCE dismissed its complaint
before trial. The city proceeded to trial in the MCCE action on its cross-complaint
against MCCE, Centennial, Morgan, Cunningham, and Morf. A jury found that MCCE
and Morf had breached SIA 1 and SIA 2. The jury awarded no damages for the breach.

                                                7
The jury reached defense verdicts as to the claims against Morgan, Centennial, and
Cunningham. After considering available equitable remedies, the court directed MCCE
and Morf to specifically perform the obligations under SIA 1 and SIA 2. The court
awarded attorney fees to the city, to be paid by MCCE and Morf, in the net amount of
$476,713. The court also directed MCCE and Morf to pay the city $24,405.45 for costs
incurred in the MCCE action. MCCE and Morf appealed the judgment and the order
awarding attorney fees in the MCCE action.
       In a decision filed in June 2009, this court reversed the trial court’s judgment in
the MCCE action insofar as it ordered Morf to specifically perform obligations under
SIA 1. (City of Novato v. MCCE Development, LLC (Jun. 17, 2009, A116957) [nonpub.
opn.].) We reasoned that Morf was not a party to SIA 1 and that his obligations under
SIA 1 were limited to the extent they could be considered covenants that run with the
land he owned. We remanded the matter for the limited purpose of considering the scope
of the equitable remedy as to Morf. In addition, because Morf was not a party to SIA 1,
we reversed the contractual attorney fee award as to him. We remanded for further
proceedings to consider whether the attorney fee award to be paid by MCCE should be
modified in light of our disposition as to Morf. In all other respects, we affirmed the trial
court’s judgment and attorney fee award. Therefore, we affirmed the judgment in the
MCCE action as it related to MCCE, and we affirmed MCCE’s obligation to pay
contractual attorney fees, leaving only the amount of the fee award to be addressed on
remand.
       On remand, the trial court modified its judgment in the MCCE action to set forth
the specific proportionate share of obligations under SIA 1 that Morf was required to
perform. The court also upheld the entire fee award of $476,713 against MCCE,
determining that, notwithstanding the reversal of the attorney fee award as to Morf, no
apportionment or reduction in the fee award was warranted. The court awarded the city
an additional $161,284.23 in fees and costs to be paid by MCCE. MCCE and Morf
appealed. Their appeal of the modified judgment in the MCCE action was pending in
this court when the trial court conducted a bench trial in the guaranty action, which is the

                                              8
subject of this appeal. In a March 2011 decision, which was filed after the trial in the
guaranty action, we affirmed the modified judgment and the attorney fee award in the
MCCE action.2
                                   Trial on the Guaranty
       The city filed the guaranty action in February 2006, just before the jury trial began
in the MCCE action. The city asserted causes of action against defendants for breach of
guaranty and declaratory relief. The city alleged that defendants had breached their
obligations under the guaranty agreement, and it sought damages, including attorney fees
and costs, arising out of the breach. In the declaratory relief cause of action, the city
contended that defendants were liable to the city for the obligations of MCCE under the
SIA’s and for attorney fees and costs incurred by the city to enforce the SIA’s. The city
sought a judicial determination that defendants are liable for MCCE’s default under the
SIA’s and for the city’s attorney fees and costs incurred to enforce the SIA’s. According
to the city, the action on the guaranty agreement was stayed during the pendency of the
first appeal in the MCCE action.
       A court trial on the guaranty action commenced in July 2010. Four witnesses
testified at the trial: (1) Walter, the city attorney, (2) defendant Morgan, (3) defendant
Cunningham, and (4) Wilson Wendt, an attorney offered as an expert witness by
defendants. After the trial court orally announced its tentative decision in favor of
defendants, the city filed a request for a statement of decision in which it identified 74
controverted issues. Among the issues the city asked the court to address was whether
defendants were liable to pay the city for its attorney fees and costs incurred in enforcing
SIA 1 and SIA 2. The court filed a statement of decision before the time had expired for
the city to file objections to the proposed statement submitted by defendants. The court
later vacated its initial statement of decision in order to consider the city’s objections.

       2
       At the city’s request, we take judicial notice of our nonpublished opinion filed on
March 30, 2011, in the MCCE action. (City of Novato v. MCCE Development, LLC
(Mar. 30, 2011, A127298) [nonpub. opn.].)

                                               9
         After considering the city’s objections, the trial court issued an amended statement
of decision and judgment (hereafter “amended statement”). As set forth in the amended
statement, the court entered judgment in favor of the defendants. With regard to the
declaratory relief cause of action, the court found that, although defendants personally
guaranteed MCCE’s obligations under SIA 2, they did not personally guarantee MCCE’s
obligations under SIA 1. The court reasoned that the guaranty agreement was limited by
its express terms to SIA 2 and SIA 3. The court rejected the city’s argument that the
cross-default provisions in the SIA’s made defendants personally liable for obligations
under SIA 1, concluding that the city’s interpretation was not objectively reasonable.
The court continued: “If the parties meant to agree that [defendants’] Personal Guaranty
extended to SIA 1 it would have been a simple matter for them to say so. Not only did
they not say so but defendants clearly stated, through counsel, that they would not enter
into a personal guaranty with respect to SIA 1.” The court stated that the city’s proposed
interpretation would turn SIA 2 “into a Trojan horse, slipping in an important and
material contract provision which was never agreed upon.” The court also noted that the
city’s proposed interpretation relied upon the subjective intent of its attorney.
         As to the issue of attorney fees, the court addressed the city’s position that
attorney fees incurred in enforcing SIA 1 and SIA 2 could not be apportioned, stating as
follows: “[The city] argues that this court has ruled the attorneys’ fees issues as to SIA 1
and SIA 2 are ‘inextricably intertwined’—citing this court’s words—so that they cannot
be segregated. That language is found in an order filed April 22, 2010 addressing a
completely different subject. It has no relevance to the issues in this trial.” Although the
court rejected the city’s reliance on a prior court order for the proposition that attorney
fees relating to enforcement of SIA 1 and SIA 2 are inextricably intertwined, the court
did not expressly address whether the attorney fee award in the MCCE action could be
apportioned between those incurred in enforcing SIA 1 and those incurred in enforcing
SIA 2.
         With regard to the breach of guaranty cause of action, the court found “that
defendants did not make a personal guaranty as to SIA 1 so there was nothing for them to

                                               10
breach.” The court further found that the city failed to “carr[y] its burden of proving that
defendants breached their Personal Guaranty as to SIA 2.”
       The city moved to set aside the amended statement and requested a new trial.
Among other things, the city argued that defendants were obligated to pay the entire
amount of attorney fees awarded in the MCCE action, contending the amount of the fees
was uncontradicted and there was no basis to apportion the fees between amounts
incurred to enforce SIA 1 and amounts incurred to enforce SIA 2. The court denied the
city’s motion. In its denial order, the court addressed the city’s argument regarding
attorney fees as follows: “[The city] now claims for the first time that the court erred in
finding that defendants had not breached the guaranty provisions of SIA 2 because in [the
earlier case] the MCCE entities were ordered to pay [the city] attorney fees and costs, and
those fees and costs have not been paid. That argument fails for two independent
reasons. First, the order in [the MCCE action] is not yet final (contrary to [the city’s]
representation), so that the MCCE entities are not yet obliged to pay the fees (CCP §43).
It is axiomatic that before a guarantor may be held liable, the primary creditor must have
defaulted in the obligation in question. Second, [the city] failed to produce any evidence
at trial on this subject. Thus, this new argument is not appropriate.”
       The trial court subsequently awarded attorney fees to defendants in the amount of
$138,198.15 in the guaranty action. The city filed a timely notice of appeal in the
guaranty action challenging the amended statement, the order denying the city’s motion
to set aside the amended statement and for a new trial, and the attorney fee award.
                                        DISCUSSION
       The focus of this appeal is on whether defendants are liable under the guaranty for
paying all or some portion of the attorney fees and costs incurred by the city in enforcing
SIA 1 and SIA 2 in the earlier MCCE action. Fundamentally, the city contends the trial
court erred in concluding that the guaranty did not extend to obligations owed under
SIA 1. It also claims the court failed to reach the question of whether defendants were
obligated to pay attorney fees and costs incurred by the city in enforcing either SIA 1 and

                                             11
SIA 2. The city further challenges the determination that it failed to establish a breach of
the guaranty.
1.     Standard of Review and General Principles Governing Guaranty Agreements
       The parties to this appeal agree that this court should apply an independent
standard of review to the interpretation of the guaranty agreement. “The interpretation of
a contract is a question of law for the court unless the interpretation depends upon the
credibility of extrinsic evidence.” (Nungaray v. Litton Loan Servicing, LP (2011) 200
Cal.App.4th 1499, 1504.) Consequently, we are not bound by the trial court’s
construction of a contract when based solely on the terms of the written instrument and
there is no conflict in the evidence. (U.S. Leasing Corp. v. duPont (1968) 69 Cal.2d 275,
284.) The parties agree that, to the extent we must consider extrinsic evidence in
interpreting the guaranty, we still apply independent review because the extrinsic
evidence concerning the guaranty negotiations is undisputed. (See Parsons v. Bristol
Development Co. (1965) 62 Cal.2d 861, 866.)
       In interpreting a contract under California law, the critical focus is upon the intent
of the contracting parties “as it existed at the time of contracting, so far as the same is
ascertainable and lawful.” (Civ. Code, § 1636.) “This intention must be ascertained from
the words used, after taking into consideration the entire contract and the circumstances
under which it was made, including the object, nature and subject matter of the contract,
and the preliminary negotiations between the parties.” (Western Camps, Inc. v. Riverway
Ranch Enterprises (1977) 70 Cal.App.3d 714, 723; see also Code Civ. Proc., § 1860.)
       A guaranty is interpreted like any other contract, with a view towards giving effect
to the parties’ intent. (U.S. Leasing Corp. v. duPont, supra, 69 Cal.2d at p. 284; RCA
Corp. v. Hunt (1982) 133 Cal.App.3d 903, 906.) “Extrinsic evidence is admissible to
interpret the instrument, to give it meaning to which it is reasonably susceptible
[citation].” (RCA Corp. v. Hunt, supra, 133 Cal.App.3d at p. 906.) To the extent public
policy may support the strict construction of surety contracts so as to protect the surety,

                                              12
that policy “has long been held inapplicable where the guarantors gained a business or
personal advantage from their guaranties.”3 (Ibid.)
       A guarantor’s obligation is based upon the guaranty agreement and not the
underlying contract the guaranty covers. (Neiderer v. Ferreira (1987) 189 Cal.App.3d
1485, 1505.) Nevertheless, “when a guaranty agreement incorporates another contract,
the two documents are read together and ‘ “[c]onstrued fairly and reasonably as a whole
according to the intention of the parties.” [Citations.]’ [Citation.] In other words, when
a party undertakes to guarantee the faithful performance of another contract, the
guarantor is contracting in reference to the other contract; ‘ “ ‘otherwise it would not
know what obligation it was assuming.’ ” ’ ” (Central Building, LLC v. Cooper (2005)
127 Cal.App.4th 1053, 1058.)
       With these principles in mind, we proceed to consider the scope of the guaranty,
which bears upon both the declaratory relief and breach of guaranty causes of action.
2.     Scope of the Guaranty
       The plain language of the guaranty agreement specifies that it applies to
obligations owed under SIA 2 and SIA 3. There is no mention of SIA 1. As the trial
court observed, it would have been a simple matter for the parties to say the guaranty
extended to SIA 1 if that was their intention. The parties’ failure to do so permits an
inference that they did not intend to include SIA 1 within the scope of the guaranty. (Cf.
Fischer v. First Internat. Bank (2003) 109 Cal.App.4th 1433, 1447.)
       The parties’ intention to limit the guaranty to SIA 2 and SIA 3 is amply supported
by extrinsic evidence of the negotiations that resulted in the guaranty agreement. The
attorney for defendants, Davidoff, rejected the idea of a personal guaranty when the

       3
        The city contends the trial court erred because it applied an incorrect legal
standard in stating that personal guaranties are to be narrowly construed. Even assuming
the legal standard employed by the court was incorrect, the city has failed to demonstrate
a showing of prejudice that would justify reversal. “We do not review the trial court’s
reasoning, but rather its ruling. A trial court’s order is affirmed if correct on any theory,
even if the trial court’s reasoning was not correct.” (J.B. Aguerre, Inc. v. American
Guarantee & Liability Ins. Co. (1997) 59 Cal.App.4th 6, 15–16.)

                                             13
SIA’s were originally negotiated. It was only after MCCE was unable to obtain a surety
bond to cover SIA 2 and SIA 3 that the city insisted on a personal guaranty. Even then,
when presented with a draft guaranty covering all of the SIA’s, Morgan refused to enter
into a personal guaranty of SIA 1. The guaranty was specifically modified so that it was
expressly limited to SIA 2 and SIA 3. A reasonable interpretation of the evidence is that
the guaranty was not intended to apply to obligations owed under SIA 1, which were
covered by a surety bond.
       It is immaterial that Walter, the city attorney, held the belief that obligations under
SIA 1 were within the scope of the guaranty, notwithstanding the deliberate removal of
any reference to SIA 1 in the guaranty and Morgan’s insistence that the guaranty not
apply to SIA 1. “ ‘[E]vidence of the undisclosed subjective intent of the parties is
irrelevant to determining the meaning of contractual language.’ [Citation.] Rather, it is
the outward manifestation or expression of assent that is controlling.” (Berman v.
Bromberg (1997) 56 Cal.App.4th 936, 948.)
       Even though the guaranty only refers to SIA 2 and SIA 3, and the objective
evidence tends to show that the parties intended to exclude SIA 1 from the scope of the
guaranty, the city nevertheless contends that obligations under SIA 1 are incorporated
into the guaranty by virtue of various provisions contained in SIA 2. First, the city relies
on the cross-default provision in SIA 2 as a basis for concluding that the guaranty extends
to SIA 1. Second, it claims the provision in SIA 2 incorporating the recitals, which it
refers to as the “incorporation paragraph,” permits the interpretation it proposes. We
address these arguments in turn.
       The cross-default provision in SIA 2 provides, in relevant part, that a breach or
default under SIA 1 or SIA 3 is deemed a breach or default under SIA 2, affording the
city “all the remedies available under this Agreement for such defaults and/or breaches of
SIA #1 and/or SIA #3.” As a starting point, the provision refers to remedies available
under SIA 2 as a consequence of a breach of SIA 1 or SIA 3. It does not purport to
incorporate the obligations or remedies from the other SIA’s into SIA 2.

                                             14
       One remedy available under SIA 2 is an award of attorney fees to a prevailing
party in litigation “arising out of or in connection with [SIA 2].” The city urges that this
remedy encompasses attorney fees incurred in enforcing SIA 1, reasoning that such fees
arise out of or are connected with SIA 2 by virtue of the cross-default provisions. The
city’s interpretation is not reasonable under the facts presented here. Considering the fee
provision together with the cross-default provision, a reasonable reading of the fee
provision is that it affords the city the right to recover fees incurred in enforcing SIA 2,
which may be deemed in default by virtue of a default or breach under either SIA 1 or
SIA 3. The cross-default provision does not import remedies from the other SIA’s,
including fee provisions in the other SIA’s, but instead allows the city to enforce SIA 2
and seek remedies under that agreement following a breach of SIA 1. Thus, reading the
guaranty agreement together with SIA 2, and in order to give effect to the parties’
intentions, a reasonable reading of the reference in SIA 2 to fees “arising out of or in
connection with this Agreement” is that it is limited to fees incurred in enforcing SIA 2.
Interpreting the fee provision in SIA 2 to apply to fees incurred in enforcing SIA 1, as the
city proposes, would contravene the intent of the parties as expressed in the guaranty and
the negotiations that led up to it.
       To the extent the city claims the guaranty applies to SIA 1 because it is considered
a remedy available under SIA 2 following a breach of SIA 1, the interpretation likewise
fails for the reason that it nullifies the plain intent of the guaranty to exclude SIA 1. The
phrase “remedies available under this Agreement” in the cross-default provision is
appropriately limited to remedies enumerated in SIA 2 for a number of reasons. First,
SIA 2 uses the term “remedies” when referring to those remedial provisions. The use of
term “remedies” in the cross-default provision presumptively means the same thing.
Second, while the city may have a legal right to invoke the guaranty for remedial
purposes, that does not make the guaranty a remedy available to the city under SIA 2. In
several other places, SIA 2 refers to remedies “under” or as “provided in” SIA 2, as
opposed to other remedies the city may have at law or in equity. In contrast with
provisions that refer to remedies other than those specified in SIA 2, the cross-default

                                              15
provision is limited to remedies “available under this Agreement.” A reasonable
interpretation of the cross-default provision, consistent with the intent of the parties to the
guaranty, is that it is limited to remedies expressly set forth in SIA 2. The guaranty is a
separate agreement and not a remedy available under the terms of SIA 2. Therefore, we
are not persuaded that the cross-default provision in SIA 2 can be interpreted to include
SIA 1 within the scope of the guaranty.
       The city claims the so-called “incorporation paragraph”—i.e., the provision in
SIA 2 incorporating the recitals as contract terms—creates an independent obligation
under SIA 2 to perform the other SIA’s. We disagree. The recital upon which the city
focuses simply reflects that the parties to SIA 2 also entered into separate SIA’s that
“provide an alternative or supplemental performance by [MCCE] for completion of the
necessary improvements . . . .” The recital does not impose an obligation to perform the
other SIA’s but simply states that the performance required by SIA 1 or SIA 3 was
“alternative or supplemental” to the performance required by SIA 2.
       The city also argues that principles of collateral estoppel establish that the three
SIA’s were one, interdependent contract. Therefore, the city argues that a guaranty as to
one SIA is a guaranty of all the SIA’s. As support for this proposition, the city cites a
passage from the trial’s court’s original decision in the MCCE action in which it stated
that the “three SIAs were part and parcel of one, contractual arrangement.” The city also
cites a passage from this court’s opinion in the MCCE action in which we stated that the
parties agreed “ ‘to memorialize the transaction in three documents.’ ” The city’s
collateral estoppel argument lacks merit.
       First, the cited passage from this court’s 2009 opinion does not establish that the
three SIA’s should be considered one agreement. We simply recited the fact that the
overall transaction was split into three agreements. Further, insofar as the trial court may
have found that the SIA’s were part of a single contractual arrangement, the finding
related to whether it was appropriate to award specific performance of SIA 1. On appeal,
we affirmed the award of specific performance as to SIA 1, but not on the ground that the
three SIA’s were part of a single contract that included a property transfer. Rather, we

                                              16
concluded the remedy was appropriate based on the difficulty of proving damages. We
specifically declined to address the alternate theory that SIA 1 was specifically
enforceable as part of an overall agreement that included a transfer of property in SIA 2.
It is well settled that an affirmance on alternative grounds eliminates any collateral
estoppel effect from the ground not approved. (Zevnick v. Superior Court (2008) 159
Cal.App.4th 76, 86; Newport Beach Country Club, Inc. v. Founding Members of Newport
Beach Country Club (2006) 140 Cal.App.4th 1120, 1132.)
       We agree with the trial court that the guaranty only extends to obligations and
remedies under SIA 2 and SIA 3. It does not encompass obligations and remedies under
SIA 1, including attorney fees incurred to enforce SIA 1.
3.     Breach of Guaranty
       The city next contends the trial court erred in concluding that the city did not meet
its burden to establish a breach of guaranty. We conclude there was no error.
       To establish a breach of a guaranty, a party must prove (1) the guarantor
guaranteed performance of a third party’s obligations, (2) the third party defaulted on its
obligations, (3) the party to whom the obligations were owed notified the guarantor of the
default and demanded performance, and (4) the guarantor failed to perform the
obligations. (See Walsh v. West Valley Mission Community College Dist. (1998) 66
Cal.App.4th 1532, 1546–1547.)
       Because the guaranty did not encompass SIA 1, the city’s claim fails with respect
to obligations owed under SIA 1. With regard to SIA 2, the trial court concluded that the
city failed to carry its burden of establishing that defendants breached the guaranty. The
city complains that the trial court failed to specify the factual findings supporting its
conclusion. While we tend to agree with the city that the trial court failed to make
required findings supporting its conclusion, the omission is harmless for reasons we
explain. (See Sperber v. Robinson (1994) 26 Cal.App.4th 736, 745 [court’s failure to
make required finding is harmless unless evidence is sufficient to support complaining
party’s position].)

                                              17
       The city focuses on two distinct sets of obligations arising out of SIA 2—the
obligation to pay the city’s attorney fees and the obligation to complete the transfer of
lots 8 through 37 to the Open Space District. The trial court addressed the attorney fee
obligation in its order denying the city’s motion for new trial and to set aside the
amended statement. It concluded that MCCE had not defaulted on an obligation to pay
court-ordered attorney fees and costs because the orders awarding attorney fees and costs
were not yet final. We agree with the trial court.
       At the time of the trial in the guaranty action, the attorney fee award in the MCCE
action was on appeal in this court. Because the award was not yet final, MCCE was not
in default on any obligation to pay attorney fees and costs. Consequently, there was no
default to trigger defendants’ obligations under the guaranty.
       The city claims that defendants waived any defense that required the city to secure
final judgments against MCCE before proceeding against defendants. Although the city
was entitled to proceed directly against defendants for a breach of SIA 2 by MCCE, there
still must have been a default to trigger the right to enforce the guaranty. In the case of
attorney fees awarded by a court, the obligation is not due until there is a final judgment.
While MCCE may have been in default under SIA 2 with respect to other obligations, it
was not in default of any obligation to pay attorney fees under SIA 2 at the time of trial in
the guaranty action.
       The city also claims that defendants were liable for breach of guaranty because
MCCE failed to fulfill its obligation under SIA 2 to complete the transfer of lots 8
through 37 to the Open Space District. As support for this claim, the city contends that
title had not yet cleared on the transfer of the properties to the Open Space District by the
time of trial in the guaranty action. Evidence at trial purportedly showed that MCCE
owed back taxes on the property and that a necessary easement across lot 7 was defective
because it had not been executed by the current owner of lot 7.
       It is unclear what relief the city sought to achieve in the guaranty action by
claiming that MCCE breached its obligation to timely transfer the property. In its
complaint, the city sought monetary damages for the breach of guaranty. Even assuming

                                             18
the city established a breach of SIA 2 as a result of the delay in completing the property
transfer to the Open Space District, the city has failed to establish that it suffered any
compensable damages as a consequence of the breach. Therefore, the city failed to prove
a cause of action for breach of guaranty.
4.       Declaratory Relief as to Fees
         The city complains that the trial court erred in failing to rule on its claim for
declaratory relief concerning whether the defendants are liable to pay for all or some
portion of the attorney fee awards in the MCCE action. As set forth below, we agree
with the city and conclude the matter must be remanded to consider the amount of fees
defendants are required to pay.
         As previously noted, the trial court ruled that the scope of defendants’ guaranty
extended only to SIA 2 and not to SIA 1. We agree with this determination for reasons
we have explained. In light of the scope of the guaranty, the question remains how the
attorney fee awards in the MCCE action should be apportioned between amounts
incurred to enforce SIA 1 and amounts incurred to enforce SIA 2. As to the
apportionment issue, the amended statement contains the following analysis: “[The city]
argues that this court has ruled the attorneys’ fees issues as to SIA 1 and SIA 2 are
‘inextricably intertwined’—citing this court’s words—so that they cannot be segregated.
That language is found in an order filed April 22, 2010 addressing a completely different
subject. It has no relevance to the issues in this trial.”
         Defendants suggest the amended statement is more than adequate, arguing it is
clear the lower court (1) issued declaratory relief, (2) rejected the notion that the attorney
fee awards cannot be segregated between SIA 1 and SIA 2, and (3) ruled that the city is
not entitled to any portion of the attorney fee awards in the MCCE action because it had
not met its burden of establishing, with particularity, the portion of the attorney fee
awards attributable solely to SIA 2. We do not agree with defendants that the amended
statement is adequate or that it necessarily supports the inferences defendants have
drawn.

                                                19
       Contrary to defendants’ characterization of the amended statement, it does not
contain factual findings concerning whether the attorney fee awards in the MCCE action
can be segregated between SIA 1 and SIA 2. Instead, the court simply rejected the
contention that it had previously decided the issue. The court did not make any
affirmative finding that it is impossible or impracticable to apportion the attorney fee
awards between SIA 1 and SIA 2.
       Part of the problem here stems from the “all or nothing” positions of the parties.
The city claims it is entitled to the entirety of the fee awards in the MCCE action because
the attorney fee provision in SIA 2 is broad enough to encompass fees incurred in
enforcing SIA 1, and that in any event it is unnecessary and impracticable to apportion
the fees because they all arise out of a common core of facts. For their part, defendants
seemed to concede in the trial court that they were responsible for some portion of the
attorney fees, urging the court in their trial brief to determine which portion of the fees
were attributable to SIA 2. Nevertheless, they claim on appeal it was the city’s burden in
the first instance to establish which fees were attributable to SIA 2. According to
defendants, because the city failed to satisfy its burden to put forth evidence of which
fees were attributable to SIA 2, it is not entitled to any portion of the fees. Thus, on the
one hand, the city claims it is entitled to all of the fees previously awarded because the
fees cannot be segregated between SIA 1 and SIA 2, whereas, on the other hand,
defendants claim the city is entitled to nothing because it failed to establish which fees
are solely attributable to SIA 2.
       For reasons we have already explained, we reject the city’s contention that the fee
provision in SIA 2 is broad enough to encompass SIA 1. The city’s broad interpretation
of the fee provision is unreasonable because it would contravene the parties’ intent to
limit the guaranty to obligations owed under SIA 2. This legal conclusion about the
scope of the fee provision in SIA 2 does not end, the inquiry, however. We are left with
the question of whether and to what extent the attorney fees awarded in the MCCE action
can be segregated between SIA 1 and SIA 2. This inquiry, which is essentially factual in
nature, has yet to be addressed by the trial court.

                                              20
       If, as the city contends, the fee issues involving SIA 1 and SIA 2 are inextricably
intertwined as a factual matter, then the court in its discretion could determine that
defendants owe the city the entirety of the fee awards in the MCCE action, without
apportionment. (See Abdallah v. United Savings Bank (1996) 43 Cal.App.4th 1101,
1111.) By contrast, if the trial court agrees with defendants that it is possible as a factual
matter to segregate the fees between SIA 1 and SIA 2, then the court should determine
the proper apportionment in the context of the declaratory relief cause of action.
       We reject defendants’ contention that the city is entitled to nothing because it has
not shown in the first instance which portion of the fees is attributable to SIA 2. The
defendants’ position effectively puts the cart before the horse and requires the city to
prove which portion of the fees is attributable to SIA 2 before there has even been a
determination that an apportionment is practically feasible. The city has consistently
taken the position that the attorney fees awarded in the MCCE action cannot practically
be apportioned between SIA 1 and SIA 2. This position is not wholly unreasonable, even
if it ultimately proves to be wrong. If the court finds that it is practically feasible to
apportion the attorney fee awards between SIA 1 and SIA 2, then the city should be
afforded an opportunity to comply with the court’s ruling and show which portion of the
fees is attributable to SIA 2.
       As a final matter, we observe that the fee award’s lack of finality as of the time of
trial does not preclude declaratory relief. Although we concluded that the breach of
guaranty cause of action fails because the attorney fee award was not final at the time of
trial, the same conclusion does not apply to the declaratory relief claim. Section 1060 of
the Code of Civil Procedure permits a declaratory relief action in cases involving an
“actual controversy” as to rights or duties of the respective parties under a written
instrument. In a case where a multiplicity of actions would result absent declaratory
relief, it is an abuse of discretion to deny declaratory relief. (See Doan v. State Farm
General Ins. Co. (2011) 195 Cal.App.4th 1082, 1095.) At the time of trial in this case,
there was an actual controversy concerning defendants’ obligation to pay the attorney
fees awarded in the MCCE action. Although the pending appeal in the MCCE action

                                               21
could have conceivably resulted in a slight reduction in the fee award, the fact remains
that MCCE was liable for fees and costs attributable to SIA 1 and SIA 2, regardless of the
outcome of the pending appeal. The apportionment issue was ripe for declaratory relief
despite the fact that the fee awards were not yet final at the time of trial.
5.     Attorney Fees
       The trial court awarded attorney fees to defendants in the guaranty action totaling
$138,198.15. The city argues that we should reverse the attorney fee award based on the
principle that an award of attorney fees “ ‘falls with a reversal of the judgment on which
it is based.’ ” (California Grocers Assn. v. Bank of America (1994) 22 Cal.App.4th 205,
220.) In this case, our reversal is limited to one issue raised in the declaratory relief
cause of action. The question remains whether our limited reversal compels reversal of
the postjudgment attorney fee award in its entirety. Under the circumstances presented
here, we conclude it does.
       In Ventas Finance I, LLC v. Franchise Tax Bd. (2008) 165 Cal.App.4th 1207,
1211–1212, the Court of Appeal reversed a postjudgment attorney fee award in its
entirety following a partial reversal of a judgment directing the Franchise Tax Board to
redetermine and limit the amount of a refund. As a consequence of its partial reversal of
the judgment, the appellate court also reversed the postjudgment attorney fee award,
reasoning that it could not say with certainty whether the trial court would exercise its
discretion to award attorney fees in the same manner in light of the limited reversal. (Id.
at p. 1212.)
       This case presents an even more clear cut example in which it is appropriate to
reverse an attorney fee award following a partial reversal. It is far from clear that the trial
court would exercise its discretion to award contractual attorney fees in the same manner
in light of our partial reversal. The reversal, while limited, goes to the heart of the
dispute between the parties—i.e., whether and to what extent defendants are liable for
attorney fees and costs awarded in the MCCE action. Accordingly, the attorney fee
award in the guaranty action must be reversed in its entirety. After the trial court issues
declaratory relief on the question of the extent to which the guaranty obligates defendants

                                              22
to pay attorney fees and costs awarded to the city in the MCCE action, the court must
reconsider the propriety and amount of the contractual attorney fee award in the guaranty
action.
                                         DISPOSITION
          We reverse and remand with respect to the declaratory relief cause of action for a
determination of the amount of the attorney fees and costs awarded in the MCCE action
that defendants are obligated to pay to the city as a consequence of their personal
guaranty. In light of our disposition, we reverse the award of attorney fees in this action.
In all other respects, we affirm the judgment. Each party shall bear its own costs on
appeal.

                                                    _________________________
                                                    McGuiness, P.J.

We concur:

_________________________
Pollak, J.

_________________________
Jenkins, J.

                                               23