Court Opinion

ID: 4194550
Source: CourtListenerOpinion
Date Created: 2017-08-09 17:11:22.700927+00
Date Added: 2024-06-11T14:40:08.613889
License: Public Domain

[Cite as Colaianni Constr., Inc. v. Ohio School Facilities Comm., 2017-Ohio-7156.]

COLAIANNI CONSTRUCTION, INC.                           Case No. 2017-00063

       Plaintiff                                       Referee Dale A. Crawford

       v.                                              DECISION OF THE REFEREE

OHIO SCHOOL FACILITIES
COMMISSION

       Defendant

        {¶1} Before the Court are three motions for the Court’s determination in this case
arising from a dispute concerning a public improvement project:

    (1) “Defendant’s Motion To Dismiss Or In The Alternative Motion For Summary
        Judgment” filed on February 16, 2017 by Defendant Ohio School Facilities
        Commission (OSFC),
    (2) “Defendant’s Motion To Dismiss Plaintiff’s First Amended Complaint Or In The
        Alternative Motion For Summary Judgment” filed on March 16, 2017 by OSFC,
        and
    (3) “Defendant’s Motion To Strike Plaintiff’s Memorandum In Opposition To
        Defendant’s Motion To Dismiss Or In The Alternative Motion For Summary
        Judgment” filed on April 20, 2017 by OSFC.

For reasons set forth below, the Referee recommends that OSFC’s “Motion to Dismiss
Or In The Alternative Motion for Summary Judgment” of February 16, 2017 should be
denied; that OSFC’s “Motion to Dismiss Plaintiff’s First Amended Complaint Or In The
Alternative Motion for Summary Judgment” of March 16, 2017 should be denied; and,
that OSFC’s “Motion To Strike Plaintiff’s Memorandum In Opposition to Defendant’s
Motion To Dismiss Or In The Alternative Motion For Summary Judgment” of April 20,
2017 should be denied.
Case No. 2017-00063                          -2-                               DECISION

   I. Background
          {¶2} On January 19, 2017, Colaianni Construction, Inc. (“Colaianni”) sued OSFC
in a breach-of-contract action pertaining to a public improvement project located in the
Indian Creek Local School District in Jefferson County, Ohio.             Thereafter, on
February 16, 2017, OSFC moved the Court to dismiss Colaianni’s Complaint pursuant
to Civ.R. 12(B)(6) and it alternatively moved for a summary judgment in its favor.
          {¶3} Fourteen days after OSFC filed its motion and alternative motion, Colaianni
filed a First Amended Complaint and contemporaneously moved for an extension to file
a memorandum in opposition to OSFC’s motions of February 16, 2017. The Court
denied Colaianni’s request for an extension.
          {¶4} On March 16, 2017, OSFC moved the Court to dismiss Colaianni’s First
Amended Complaint pursuant to Civ.R. 12(B)(6) and moved in the alternative for
summary judgment in its favor. Colaianni sought an extension to respond to OSFC’s
motions of March 16, 2017 and leave to exceed this Court’s local rules pertaining to
page limitations for opposing memoranda.           The Court granted in part Colaianni’s
request, ordering Colaianni to file a memorandum in opposition on or before April 6,
2017 and limiting its memorandum to 20 pages, exclusive of attachments.
          {¶5} On April 6, 2017, Colaianni filed a response in opposition. Fourteen days
later, on April 20, 2017, OSFC moved the Court to strike Colaianni’s response of April 6,
2017. On May 4, 2017, Colaianni filed a response in opposition to OSFC’s motion to
strike.

   II. Because OSFC’s Motion to Dismiss and Alternative Motion for Summary
       Judgment of February 16, 2017 are moot, those motions should be denied.
          {¶6} In the Court’s entry denying Colaianni’s request for an extension to file a
response to OSFC’s motions of February 16, 2017, the Court noted: “OSFC’s motion to
dismiss and alternative motion for summary judgment is [sic] directed toward
Colaianni’s original complaint, which is no longer at issue due to Colaianni’s filing of a
Case No. 2017-00063                           -3-                                  DECISION

first amended complaint as a matter of course in accordance with Civ.R. 15(A). * * *
Colaianni’s first amended complaint is the pleading at issue, which requires OSFC to file
a responsive pleading or a motion permitted by the Ohio Rules of Civil Procedure.”
Because OSFC’s motion and alternative motion of February 16, 2017 are directed
toward a pleading that is no longer at issue, namely Colaianni’s original complaint, the
Court finds that OSFC’s motions of February 16, 2017 are moot. See City of Grove City
v. Clark, 10th Dist. Franklin No. 01AP-1369, 2002-Ohio-4549, ¶ 11, quoting Culver v.
City of Warren, 84 Ohio App. 373, 393, 83 N.E.2d 82 (11th Dist.1948) (citations omitted)
(“‘Actions or opinions are described as “moot” when they are or have become fictitious,
colorable, hypothetical, academic or dead.’”). And since OSFC’s motion and alternative
motion of February 16, 2017 are moot, the Court determines that those motions should
be denied because courts generally do not resolve issues or controversies that are
moot. See State v. Marcum, 2015-Ohio-5237, 54 N.E.3d 719, ¶ 6 (10th Dist.); Lingo v.
Ohio Cent. R.R., 10th Dist. Franklin No. 05AP-206, 2006-Ohio-2268, ¶ 20.

   III. OSFC’s “Motion To Strike Plaintiff’s Memorandum In Opposition To
        Defendant’s Motion To Dismiss Or In The Alternative Motion For Summary
        Judgment” filed on April 20, 2017 should be denied.
       {¶7} OSFC has moved the Court to strike Colaianni’s memorandum in opposition
of April 6, 2017 “in its entirely [sic],” as well as certain attachments to Colaianni’s filing,
“including the Affidavit of David Wodesky, and specifically affidavit statement numbers
13 through 20 inclusive; MKC Sheet 2.07 dated June 2015; Colaianni letter to the
Project Team dated October 2, 2015; and, the [school district’s] letter to Colaianni dated
November 5, 2015” because, according to OSFC, those items constitute privileged
mediation communications under R.C. 2710.03 and Evid.R. 408. With its motion, OSFC
filed certain affidavits and associated exhibits under seal for an in camera inspection by
the Court.
       {¶8} In opposition, Colaianni contends that communications identified by OSFC
as objectionable are admissible because they pertain to Colaianni’s right, as well as its
Case No. 2017-00063                         -4-                                 DECISION

attempts, to cure and that the documents that OSFC seeks to strike do not reference
mediation or settlement negotiations. Colaianni reasons that, if the Court were to strike
communications of October 2015 and November 2015, this would mean that Colaianni’s
contract balance has not accrued because it has not been provided an opportunity to
cure outside of mediation.
       {¶9} Whether to grant or deny OSFC’s motion to strike is within this Court’s
discretion. See Bester v. Shilo, 8th Dist. Cuyahoga No. 89355, 2007-Ohio-6987, ¶ 18
(“Our standard of review for a motion to strike is abuse of discretion by the trial court”).
Subject to exceptions, a mediation communication is privileged. R.C. 2710.03; 2710.05.
Pursuant to R.C. 2710.01, as used in R.C. 2710.01 to 2710.10, a “mediation
communication” means “a statement, whether oral, in a record, verbal or nonverbal, that
occurs during a mediation or is made for purposes of considering, conducting,
participating in, initiating, continuing, or reconvening a mediation or retaining a
mediator.” The Court has reviewed the items identified by OSFC as objectionable and
the materials that OSFC filed under seal with its motion to strike. The Court finds that
Wodesky’s affidavit, a copy of Colaianni’s letter dated October 2, 2015, and a copy of
the school district’s letter dated November 5, 2015 do not constitute nonverbal
statements that are made for the purposes of considering, conducting, participating in,
initiating, continuing, or reconvening a mediation or retaining a mediator. Rather, the
objectionable items pertain to a proposal that resulted from mediation after the
mediation concluded.     See Hopes v. Barry, 11th Dist. Ashtabula No. 2010-A-0042,
2011-Ohio-6688, ¶ 35 (rejecting argument that emails constituted a mediation
communication) (“In this matter, the emails sent from Attorney Piper were not made
‘during a mediation.’ They were sent several weeks after the mediation ended”). The
Court determines that these items identified by OSFC as objectionable are not
“mediation communications,” as set forth in R.C. 2710.01.
       {¶10} Moreover, although OSFC has filed under seal an affidavit of attorney
Desmond J. Cullimore containing an averment that MKC Sheet 2.07 dated June 2015 is
Case No. 2017-00063                           -5-                                  DECISION

part of a mediation communication, the Court finds that such an averment is tantamount
to a determination concerning a question of law, which is within the Court’s province to
determine. See Henley v. City of Youngstown Bd. of Zoning Appeals, 90 Ohio St. 3d
142, 148, 735 N.E.2d 433 (2000) (“The application of Section 80 [of a city zoning
ordinance] to the facts is a ‘question of law’—‘an issue to be decided by the judge,
concerning the application or interpretation of the law.’ Black’s Law Dictionary
(7 Ed.1999) 1260. That the application of Section 80 to this case involved a
consideration of facts or the evidence did not turn this question into a question of fact.
O’Day v. Webb (1972), 29 Ohio St. 2d 215, 58 Ohio Op. 2d 424, 280 N.E.2d 896,
paragraph two of the syllabus”). Notwithstanding attorney Cullimore’s averment, the
Court is not convinced that MKC Sheet 2.07 constitutes a mediation communication, as
set forth in R.C. 2710.01. The Court concludes that MKC Sheet 2.07 should not be
stricken.
       {¶11} Additionally, the Court determines that a striking of Colaianni’s entire
response is not warranted as Colaianni’s attachments to its response include a copy of
the parties’ contract with Wodesky’s affidavit certifying that the copy of the contract is
true and accurate. And insofar as the evidence proffered by Colaianni with its response
in opposition is offered to rebut OSFC’s contention of undue delay—an argument raised
by OSFC’s assertion of the doctrine of laches in OSFC’s filing of March 16, 2017—such
evidence is permitted by Evid.R. 408, which provides:

            a. Evidence of (1) furnishing or offering or promising to furnish, or
               (2) accepting or offering or promising to accept, a valuable
               consideration in compromising or attempting to compromise a claim
               which was disputed as to either validity or amount, is not admissible
               to prove liability for or invalidity of the claim or its amount. Evidence
               of conduct or statements made in compromise negotiations is
               likewise not admissible. This rule does not require the exclusion of
               any evidence otherwise discoverable merely because it is
               presented in the course of compromise negotiations. This rule also
               does not require exclusion when the evidence is offered for another
               purpose, such as proving bias or prejudice of a witness, negativing
Case No. 2017-00063                         -6-                              DECISION

              a contention of undue delay, or proving an effort to obstruct a
              criminal investigation or prosecution.

(Emphasis added.) Upon review, the Court determines that OSFC’s “Motion To Strike
Plaintiff’s Memorandum In Opposition To Defendant’s Motion To Dismiss Or In The
Alternative Motion For Summary Judgment” of April 20, 2017 should be denied.

   IV. Because OSFC has not sustained its burden on summary judgment,
       OSFC’s motion for summary judgment filed on March 16, 2017 should be
       denied.
       A. First Amended Complaint
       {¶12} In its First Amended Complaint, Colaianni asserts that its lawsuit “is an
action to recover money damages for breach of a construction contract arising from or
relating to Colaianni’s work as the combination general trades contractor on a project
known as the New Middle School Project (the ‘Project’).” (First Amended Complaint, ¶
1.) Colaianni contends that OSFC is a “co-owner” of the project with the Indian Creek
Local School District, and that OSFC and the school district approved a contract with
Colaianni. (First Amended Complaint, ¶ 6, 7.) Colaianni alleges:
      The school district hired MKC Associates, Inc. (MKC) as the architect for the
       project.
      OSFC and the school district, through MKC, were responsible for furnishing
       plans and specifications that were necessary for Colaianni to complete its work.
      MKC, acting as OSFC’s agent, was responsible for processing and responding to
       shop drawings, submittals, and requests for interpretation (RFIs).
      Colaianni’s work started about 8 months late through no fault of it or other
       contractors and its work was continually delayed and disrupted by a variety
       factors outside of Colaianni’s control.
      Colaianni completed the project in December 2012 such that students were able
       to use the school building for the spring semester.
Case No. 2017-00063                       -7-                                DECISION

     In June 2013 Colaianni, through a subcontractor, Shelly & Sands, returned to the
      project to repair punch-list items and address concerns. According to Colaianni,
      paving repairs were effectuated without any objection of the architect or
      construction manager who supervised the activities.
     OSFC and the school district complained about water on the pavement of the
      asphalt parking lot and they hired Mannik Smith to investigate.
     Mannik Smith issued a report on June 27, 2014. Borings taken by Mannik Smith
      showed some deviations in paving thickness but, according to Colaianni, “the
      average actual total paving system (stone and asphalt) for the parking lot is
      within 99.62% and the total paving design thickness.” (First Amended Complaint,
      ¶ 18.) And according to Colaianni, assuming that a certain boring is disallowed
      because it was compromised by a broken waterline during drilling, the average
      actual thickness “of the roadway” exceeds the design thickness by .20 inches.
      (First Amended Complaint, ¶ 18.)
     Shelly & Sands confirmed that compaction and density were fully achieved and
      that it provided documentation to that effect, as verified by a third-party testing
      agency.
     Colaianni has maintained that subsurface water continues to degrade the
      subgrade and migrate to the surface of the parking lot. Colaianni states that it
      “concurs with the Mannik Smith report with respect to its conclusions that the
      design of the asphalt paving system failed to adequately address the presence of
      subsurface water that the geotech report said should have been mitigated with
      underdrains and a geotech fabric.” (First Amended Complaint, ¶ 20.)
     On November 5, 2015, the “Co-Owners” informed Colaianni through a letter that
      they would not pay Colaianni “its Contract Balance and thereby breached the
      Contract.” (First Amended Complaint, ¶ 22.) Colaianni alleges that its claim for
      its contract balance “arose no earlier than November 5, 2015 when the Co-
Case No. 2017-00063                        -8-                                DECISION

       Owners informed Colaianni that it [sic] would be ‘retaining another contractor to
       correct the defective and non-conforming work.’”      (First Amended Complaint,
       ¶ 24.)
      Colaianni has complied with all provisions of the contract and the “Co-Owners”
       have failed to comply with Articles 5 and 9 of the General Conditions of the
       contract and the “Co-owners” have no reason to withhold the remaining contract
       balance of $267,627.55.
      Dispute resolutions pertaining to claims under Article 8 of the contract do not
       apply and OSFC and the school district “have refused to pay the Contract
       Balance or arbitrate the dispute leaving Colaianni no choice but to initiate this
       action.” (First Amended Complaint, ¶ 28.)
      Colaianni “attempted to arbitrate its dispute over [an] escrow agreement with
       Indian Creek and the Courts ultimately ruled that this dispute would have to
       proceed in the Ohio Court of Claims.” (First Amended Complaint, ¶ 8.)

       {¶13} Colaianni presents two causes of action labeled as counts: (1) “Count One-
Breach of Contract” and (2) “Count Two – Declaratory Judgment.” As to its breach-of-
contract claim, Colaianni asserts that it and OSFC, through the school district, entered
into a contract for construction services related to the project; that Colaianni performed
its obligations under the contract and “satisfied all conditions precedent to recovery”
(First Amended Complaint, ¶ 31); that OSFC and the school district breached the
contract on November 5, 2015 by refusing to pay Colaianni a remaining contract
balance of $267,627.55; and that Colaianni is entitled to recover from OSFC and the
school district “its unpaid Contract Balance, interest accrued, and other damages in an
amount not fully ascertained but which at trial will be proven to be well in excess of
$25,000.00.” (First Amended Complaint, ¶ 30-33.) As to its declaratory-judgment claim,
Colaianni “contends that any and all alleged problems with the parking lot were the
proximate result of the design of the asphalt paving system which failed to adequately
Case No. 2017-00063                         -9-                                   DECISION

address the presence of subsurface water.”            (First Amended Complaint, ¶ 37.)
Colaianni seeks a declaratory judgment “to determine and to declare the parties’
respective rights, status and other legal relations under the Contract and Contract
Documents, including but not limited to whether Colaianni has any responsibility to
perform or pay for additional work on the parking lot.” (First Amended Complaint, ¶ 38.)
Colaianni also seeks a declaration that “the problems with the parking lot were
proximately caused by a design error of the OSFC’s agent, and not by any defective
work by Colaianni and/or its subcontractor; and further that Colaianni is not responsible
for any additional work on the parking lot as proposed by the OSFC.” (First Amended
Complaint, ¶ 39.)

      B. OSFC’s Motions and Colaianni’s Response
      {¶14} On March 16, 2017, OSFC moved pursuant to Civ.R. 12(B)(6) for an order
dismissing Colaianni’s First Amended Complaint for failure to state a claim upon which
relief may be granted and it moved in the alternative for an order granting summary
judgment in its favor. With its filing OSFC appended a memorandum and attachments:
      (1) a copy of an affidavit of Desmond J. Cullimore, Esq. dated February 14, 2017
      wherein Cullimore avers that:
         he is an attorney with the law firm of Bricker & Eckler, LLP;
         he is legal counsel to the Indian Creek Local School District;
         he has personal knowledge of the matters stated in the affidavit; and
         on November 18, 2013, on behalf of the school district, he executed and sent
          via email and certified mail a letter to Colaianni titled “Indian Creek Local
          School District, New Middle School Project, Disapproval of Application for
          Payment No. 18, and Payments Withhheld for Defective/Non-Conforming
          Work, attached hereto as Exhibit 1,” and
      (2) a copy of the letter referenced in Cullimore’s affidavit (Exhibit 1).
Case No. 2017-00063                         -10-                               DECISION

In its memorandum OSFC contends that (1) all of Colaianni’s breach-of-contract claims
are time barred; (2) Colaianni’s declaratory-relief claim accrued more than four years
before Colaianni filed suit and is time barred; (3) OSFC is entitled to judgment in its
favor as a matter of law; (4) Colaianni’s failure to initiate or complete the contractual
dispute resolution process divests this Court of jurisdiction; (5) Colaianni has not stated
an appropriate claim for declaratory relief and has not joined the parties statutorily
required for this Court to even consider such relief; and (6) Colaianni’s claims are
barred by the doctrine of laches.
       {¶15} On April 6, 2017, Colaianni filed a response in opposition with attendant
exhibits. With its response Colaianni attached a copy of an affidavit of David Wodesky
dated April 5, 2017, wherein Wodesky attests that he is “Project Manager for Colaianni
Construction, Inc. * * * and [he has] personal knowledge of the facts and circumstances
described in this Affidavit.” In this affidavit, Wodesky avers that:
      A contract (Exhibit A-1), attached to Wodesky’s affidavit is a true and accurate
       copy of Colaianni’s contract with OSFC and the contract incorporates other
       documents including the project’s General Conditions (GC) and Definitions;
      A copy of the project’s General Conditions (Exhibit A-2) attached to Wodesky’s
       affidavit is true and accurate;
      A copy of the contract’s definitions attached to Wodesky’s affidavit (Exhibit A-3)
       is true and accurate;
      A “Parking Lot Report” (excluding attachments) appended to Wodesky’s affidavit
       (Exhibit A-4) is a true and accurate copy and “was released to Colaianni on
       July 11, 2014”;
      On October 2, 2015, Colaianni “submitted change order pricing under Article 7
       for the additional cost to add underdrainage.” A copy of an October 2, 2015 letter
       and change order request (Exhibit A-5) attached to the affidavit are true and
       accurate; and
Case No. 2017-00063                        -11-                                 DECISION

      A copy of a November 5, 2015 letter from the school district’s superintendent to
       Colaianni appended to Wodesky’s affidavit is true and accurate.

   In its response, Colaianni contends that OSFC has not carried its burden to prove
   that there is no dispute that Colaianni’s claim for its contract balance accrued
   beyond the two-year statute of limitations contained in R.C. 2743.16(A). Colaianni
   further contends that OSFC has not provided a reason for this Court to depart from
   its recent findings that “the Article 8 process” does not apply to a contractor’s claim
   for a contract balance based on the plain language of Article 8.

       C. Analysis
       {¶16} OSFC’s filing is comprised of two motions: (1) a Civ.R. 12(B)(6) motion and
(2) an alternative motion for summary judgment; the motions raise an affirmative
defense, namely, that Colaianni’s lawsuit is time-barred. See Civ.R. 8(C) (indicating
that a defense of “statute of limitations” is an affirmative defense). In view of OSFC’s
filing that combines a Civ.R. 12(B)(6) motion and a summary judgment motion, the
Court finds that Savoy v. Univ. of Akron, 10th Dist. Franklin No. 11AP-183, 2012-Ohio-
1962 is apt and offers guidance about how to proceed. In Savoy at ¶ 5-6, the Tenth
District Court of Appeals stated:

          b. In order for a trial court to dismiss a complaint under
             Civ.R. 12(B)(6) for failure to state a claim upon which relief can be
             granted, it must appear beyond doubt that the plaintiff can prove no
             set of facts in support of the claim that would entitle plaintiff to the
             relief sought. O’Brien v. Univ. Community Tenants Union, Inc., 42
Ohio St. 2d 242, 245, 327 N.E.2d 753 (1975). When addressing
             such motion, the court must take the allegations in the complaint as
             true and draw any reasonable inferences in favor of the nonmoving
             party. Id. * * *.

          c. “A complaint may be dismissed under Civ.R. 12(B)(6) for failing to
             comply with the applicable statute of limitations when the complaint
             on its face conclusively indicates that the action is time-barred.”
             (Emphasis added.) Ohio Bur. of Workers’ Comp. v. McKinley, 103
Case No. 2017-00063                        -12-                                 DECISION

             Ohio St.3d 156, 2011-Ohio-4432, ¶ 13, citing Doe v. Archdiocese of
             Cincinnati, 109 Ohio St. 3d 491, 2006-Ohio-2625, ¶ 11, 849 N.E.2d
268. This holding, however, must be read in conjunction with the
             general rule that an “affirmative defense is generally not properly
             raised in a Civ.R. 12(B)(6) motion, as it also typically requires
             reference to materials outside the complaint.” Jude v. Franklin Cty.,
             10th Dist. No. 03AP-1053, 2004-Ohio-2528, ¶ 11, citing Helman v.
             EPL Prolong, Inc., 139 Ohio App. 3d 231, 2000-Ohio-2593, 743
N.E.2d 484 (7th Dist.2000). The various tolling exceptions to Ohio’s
             statutes of limitation, including the refiling provisions of the savings
             statute, will often invoke questions of fact that may go beyond the
             scope of the bare dates set forth in the complaint. Because of this,
             the question of whether a complaint, on its face, “conclusively” fails
             as time-barred often requires more than mere reference to the
             overlong interval between the injury and commencement of the
             action. “For there to be a conclusive showing in that regard, the
             complaint must show both: (1) the relevant statute of limitations;
             and (2) the absence of factors which would toll the statute or make
             it inapplicable.” Id.

Savoy further states: “Under these conditions, a better procedure is to address
affirmative defenses by way of a motion for summary judgment that will allow
introduction of additional facts beyond the complaint.” Savoy at ¶ 7.
      {¶17} Applying the reasoning of Savoy, the Court determines that in this
circumstance the “better procedure” is to construe OSFC’s “Motion To Dismiss Plaintiff’s
First Amended Complaint Or In The Alternative Motion For Summary Judgment” as a
motion for summary judgment.
      {¶18} Civ.R. 56(C) pertains to motions and proceedings for summary judgment.
In State ex rel. Grady v. State Emp. Relations Bd., 78 Ohio St. 3d 181, 183, 677 N.E.2d
343 (1997), construing Civ.R. 56(C), the Ohio Supreme Court stated: “Civ.R. 56(C)
provides that before summary judgment may be granted, it must be determined that
(1) no genuine issue as to any material fact remains to be litigated, (2) the moving party
is entitled to judgment as a matter of law, and (3) it appears from the evidence that
reasonable minds can come to but one conclusion, and viewing such evidence most
Case No. 2017-00063                       -13-                                DECISION

strongly in favor of the nonmoving party, that conclusion is adverse to the party against
whom the motion for summary judgment is made. Temple v. Wean United, Inc. (1977),
50 Ohio St. 2d 317, 327, 4 O.O.3d 466, 472, 364 N.E.2d 267, 274.” And in Dresher v.
Burt, 75 Ohio St. 3d 280, 293, 662 N.E.2d 264 (1996) the Ohio Supreme Court held that

          d. a party seeking summary judgment, on the ground that the
             nonmoving party cannot prove its case, bears the initial burden of
             informing the trial court of the basis for the motion, and identifying
             those portions of the record which demonstrate the absence of a
             genuine issue of material fact on the essential element(s) of the
             nonmoving party’s claims. The moving party cannot discharge its
             initial burden under Civ.R. 56 simply by making a conclusory
             assertion that the nonmoving party has no evidence to prove its
             case. Rather, the moving party must be able to specifically point to
             some evidence of the type listed in Civ.R. 56(C) which affirmatively
             demonstrates that the nonmoving party has no evidence to support
             the nonmoving party’s claims. If the moving party fails to satisfy its
             initial burden, the motion for summary judgment must be denied.
             However, if the moving party has satisfied its initial burden, the
             nonmoving party then has a reciprocal burden outlined in Civ.R.
             56(E) to set forth specific facts showing that there is a genuine
             issue for trial and, if the nonmovant does not so respond, summary
             judgment, if appropriate, shall be entered against the nonmoving
             party.

(Emphasis sic.) Here, OSFC’s motion for summary judgment and Colaianni’s response
raise issues concerning (1) whether this court has jurisdiction of this cause and
(2) whether any genuine issue of material fact remains to be litigated as to whether
Colaianni’s action is time-barred, with this Court viewing the evidence most strongly in
favor of Colaianni, as the nonmoving party.
      {¶19} For purposes of its motions of March 16, 2017, OSFC appears to concede
that it is a state institution and it is a proper party before the Court. See generally
R.C. 3318.30(A) (“There is hereby created the Ohio school facilities commission as an
independent agency of the state within the Ohio facilities construction commission,
which is created under section 123.20 of the Revised Code”); R.C. 2743.01(A) (defining
Case No. 2017-00063                         -14-                                 DECISION

the term state to mean “the state of Ohio, including, but not limited to * * * agencies, and
other instrumentalities of the state”); R.C. 2743.02(A)(1) (waiver of the state’s immunity
from liability and the state’s consent to be sued and have its liability determined in the
Ohio Court of Claims in accordance with the same rules applicable to suits between
private parties subject to some limitations).
       {¶20} Despite OSFC’s contention that Colaianni’s failure to initiate or complete
the contractual dispute resolution process divests this Court of jurisdiction, this Court
has, as a matter of law, exclusive, original jurisdiction in this cause in accordance with
R.C. 2743.01(A)(1), which provides:

          e. There is hereby created a court of claims. The court of claims is a
             court of record and has exclusive, original jurisdiction of all civil
             actions against the state permitted by the waiver of immunity
             contained in section 2743.02 of the Revised Code and exclusive
             jurisdiction of the causes of action of all parties in civil actions that
             are removed to the court of claims. The court shall have full equity
             powers in all actions within its jurisdiction and may entertain and
             determine all counterclaims, cross-claims, and third-party claims.

Moreover, any potential claim of a lack of personal jurisdiction by OSFC is of little
moment because, in this instance, OSFC has waived the issue of personal jurisdiction
by its appearance and submissions. See Maryhew v. Yova, 11 Ohio St. 3d 154, 156,
464 N.E.2d 538 (1984) (“It is rudimentary that in order to render a valid personal
judgment, a Court must have personal jurisdiction over the defendant. This may be
acquired either by service of process upon the defendant, the voluntary appearance and
submission of the defendant or his legal representative, or by certain acts of the
defendant or his legal representative which constitute an involuntary submission to the
jurisdiction of the Court. The latter may more accurately be referred to as a waiver of
certain affirmative defenses, including jurisdiction over the person under the Rules of
Civil Procedure”). Notably, the Ohio Supreme Court has determined: “Once a tribunal
has jurisdiction over both the subject matter of an action and the parties to it, ‘* * * the
Case No. 2017-00063                          -15-                                 DECISION

right to hear and determine is perfect; and the decision of every question thereafter
arising is but the exercise of the jurisdiction thus conferred * * *.’” State ex rel. Pizza v.
Rayford, 62 Ohio St. 3d 382, 384, 582 N.E.2d 992 (1992), quoting Sheldon’s Lessee v.
Newton, 3 Ohio St. 494, 499 (1854).
       {¶21} Additionally, General Conditions (GC) Article 1.1.3.2 of the parties’ contract
states: “The Ohio Court of Claims shall be the exclusive jurisdiction for any action or
proceeding by the Contractor or the Contractor’s Surety for any money damages
concerning any agreement or performance under the Contract Documents or in
connection with the Project.” Thus, the parties’ contract supports a view that jurisdiction
in this forum is proper.
       {¶22} Upon review, the Court finds that it has jurisdiction over both the subject
matter at issue and the parties before it.
       {¶23} Besides claiming that this Court lacks jurisdiction, OSFC urges that all of
Colaianni’s breach-of-contract claims are time barred, that Colaianni’s claims are barred
by the doctrine of laches, and that that Colaianni’s declaratory-relief claim accrued more
than four years before Colaianni filed suit and is time barred and that Colaianni has not
joined parties statutorily required for this court to consider declaratory relief.         As
discussed below, the Court finds these arguments are not persuasive.
       {¶24} According to R.C. 2743.16(A), subject to exceptions not relevant here, civil
actions against the state permitted by R.C. 2743.01 to 2743.20 are required to “be
commenced no later than two years after the date of accrual of the cause of action or
within any shorter period that is applicable to similar suits between private parties.”
Compare R.C. 2305.06 (statute of limitations for written contracts) (“Except as provided
in sections 126.301 and 1302.98 of the Revised Code, an action upon a specialty or an
agreement, contract, or promise in writing shall be brought within eight years after the
cause of action accrued”). Therefore, applying R.C. 2743.16(A) to Colaianni’s breach-
of-contract claim against OSFC, its claim for a breach of contract “is subject to the
R.C. 2743.16(A) two-year statute of limitations.” Marok v. Ohio State Univ., 10th Dist.
Case No. 2017-00063                        -16-                                 DECISION

Franklin No. 13AP-12, 2014-Ohio-1184, ¶ 19, citing Bell v. Ohio State Bd. of Trustees,
10th Dist. Franklin No. 06AP-1174, 2007-Ohio-2790, ¶ 19.
       {¶25} In Columbus Green Bldg. Forum v. State, 2012-Ohio-4244, 980 N.E.2d 1, ¶
27 (10th Dist.), quoting Children’s Hosp. v. Ohio Dept. of Pub. Welfare, 69 Ohio St. 2d
523, 526, 433 N.E.2d 187 (1982), the Tenth District Court of Appeals discussed the
concept of an accrual of a cause of action, explaining: “A cause of action does not
ordinarily accrue until actual damage occurs; ‘when one’s conduct becomes presently
injurious, the statute of limitations begins to run.’” The appellate court, however, further
explained:

          f. With specific reference to contract claims, the Supreme Court of
             Ohio has held that “‘[a] cause of action for breach of contract does
             not accrue until the complaining party suffers actual damages as a
             result of the alleged breach.’” Kincaid v. Erie Ins. Co., 128 Ohio
             St.3d 322, 2010-Ohio-6036, ¶ 13, quoting Midwest Specialities, Inc.
             v. Firestone Tire & Rubber Co., 42 Ohio App. 3d 6 (9th Dist.1988).
             Although the complaining party may suffer actual damage at the
             time of the breach, that is not always the case. See Bell at ¶ 27 (“A
             cause of action for breach of contract accrues when the breach
             occurs or when the complaining party suffers actual damages.”).
             (Emphasis added.)

Columbus Green Bldg. Forum at ¶ 27.

       {¶26} OSFC contends that all of Colaianni’s breach-of-contract claims are time
barred because activities asserted in paragraph 14 of Colaianni’s complaint (listing
alleged factors that delayed and disrupted Colaianni’s work on the project) “would have
arisen during the construction process such that the latest time any claim related thereto
could have accrued would be at the construction was complete” and, as a
consequence, “any claim arising from the allegations in paragraph 14 must have
accrued in or prior to December 2012.”        (OSFC Motion, 3.)      And with respect to
Colaianni’s allegation that its subcontractor repaired punch-list items in June 2013,
OSFC asserts: “Even assuming that the two-year period for initiating litigation began to
Case No. 2017-00063                       -17-                                DECISION

run in June 2013, Colaianni initiated litigation over 3 and half years after doing the
limited remedial work. Thus, there are no provable facts that Colaianni’s claims are not
barred by the statute of limitations.” OSFC states: “The question of when Colaianni’s
contract balance claim accrued is simple – when was it owed the money? Colaianni
alleged it was owed the money since December of 2012 because it completed
construction and fulfilled all necessary contract requirements entitling it to payment.
Colaianni also alleged its work was defect free as of June 2013. In order for Colaianni’s
allegation that the owners’ decision to hire someone else to fix Colaianni’s defective and
non-conforming work actually marks the accrual of Colaianni’s contract balance claim, *
* * Colaianni’s refusal to actually correct the defective and non-conforming work would
have to somehow toll the applicable stature of limitations.”     (OSFC Motion, 4.)      In
support, OSFC relies on Exhibit 1 (letter dated November 18, 2013 from the school
district’s counsel, attorney Desmond Cullimore, to Vince Colaianni, president of
Colaianni Construction, Inc.), which OSFC appended to its filing of March 16, 2017.
      {¶27} In opposition, Colaianni asserts that the first time it became aware that
OSFC and the school district rejected its proposed remedy to address the Mannik
Smith’s Parking Lot Report occurred when the school district’s superintendent, T.C.
Chappelear, issued a letter on November 5, 2015 (Exhibit A-6) in response to a letter of
Colaianni dated October 2, 2015 wherein Colaianni sought direction whether the school
district and OSFC intended to proceed with modifications to the parking lot that were
discussed and identified in MKC Sheet 2.07 of June 2015. According to Colaianni, it
was not until Chappelear’s letter of November 5, 2015 that Colaianni became aware
that its attempt to remedy the situation initiated by MKC’s revised parking lot design was
not acceptable.
      {¶28} In OSFC’s Exhibit 1 (letter dated November 18, 2013), attorney Cullimore
informed Vince Colaianni that “on October 29, 2013, and in accordance with GC 5.3,
Bowen [Construction Manager] informed CCI [Colaianni Construction, Inc.] that the
Owners are proceeding to supplement CCI’s work with another contractor and that all
Case No. 2017-00063                        -18-                                 DECISION

costs to correct this defective work will be deducted from CCI’s contract.” Cullimore
stated: “As a result of CCI’s * * * failure to construct the parking lot in accordance with
the Contract Documents, the District is declining to approve Application for Payment
No. 18 and is withholding further payment from CCI to correct defective and/or non-
conforming work. Once the investigation is complete, we will provide CCI with the
results of the investigation. In addition, to the extent the defective parking lot was not
the subject of the prior notice of defective work, CCI will be provided the opportunity to
correct the defective parking lot in accordance with the Contract Documents.” Viewing
this evidence in favor of Colaianni, as required by Civ.R. 56(C), the Court determines
that a trier-of-fact could conclude that as of November 2013 Colaianni was on notice
that its work pertaining to the parking lot was defective, that its work would be
supplemented by another contractor, and that Colaianni would be given an opportunity
to cure its purportedly defective work after an investigation was completed.
       {¶29} By comparison, in Colaianni’s Exhibit A-6 (letter dated November 5, 2015)
Superintendent Chappelear informed Colaianni that “in accordance with the Co-Owners
right under GC 5.3 [right to prosecute work and backcharge contractor], the Co-Owners
will be retaining another contractor to correct the defective and non-conforming work of
Colaianni.” Chappelear also stated: “The estimated costs to correct the defective work
of Colaianni exceed the unpaid balance of the Contract Sum, which Colaianni indicates
is $267,627.55. * * * As a result of [Colaianni’s] failure to perform its work in accordance
with the Contract Documents, the Co-Owners will continue to withhold payment from
[Colaianni] to correct defective and/or non-conforming work.” Chappelear further stated:
“As a contractual dispute, Colaianni is required to follow the dispute resolution
procedures in Article 8 of the General Conditions of the Contract.”            Chappelear
continued: “If Colaianni seeks to compel arbitration, the Co-Owners will oppose such
action * * *.” Viewing this evidence in favor of Colaianni, as required by Civ.R. 56(C),
the Court determines that a trier-of-fact could conclude that (1) as of November 2015
Colaianni was on notice that OSFC would be withholding $267,627.55 because, in
Case No. 2017-00063                       -19-                                DECISION

OSFC and the school district’s view, Colaianni failed to perform in accordance with the
parties’ contract; (2) the school district planned to retain another contractor due to
Colaianni’s purportedly defective work; and (3) OSFC and the school district opposed
arbitration.
       {¶30} After considering the evidence, including Exhibit 1 and Exhibit A-6 in favor
of Colaianni, as required by Civ.R. 56(C), the Court determines that a trier-of-fact could
conclude that a genuine issue of material fact exists whether Colaianni’s breach-of-
contract claim accrued at the latest in June 2013—as OSFC urges—or no earlier than
November 5, 2015—as Colaianni contends.
       {¶31} Besides urging that Colaianni’s claims are statutorily time-barred, OSFC
contends that Colaianni’s claims are barred by the doctrine of laches because,
according to OSFC, Colaianni has unreasonably delayed bringing its action and it has
alleged no excuse for the delay.     Colaianni disputes that it delayed in bringing its
lawsuit.   In opposition, Colaianni represents that, after it received the “Co-owner’s”
response of November 5, 2015, it filed a complaint in the Jefferson County Common
Pleas Court on December 10, 2015, seeking arbitration and the appointment of an
arbitrator for the purpose of obtaining retainage funds that were held in an escrow
account. Colaianni maintains that, after the common pleas court issued an order on
March 3, 2016 that compelled the school district to arbitrate, the school district
appealed.      According to Colaianni, the appellate court reversed the common pleas
court, determining that the retainage funds were not subject to arbitration because the
responsible party was OSFC—not the school district.
       {¶32} In State ex rel. Polo v. Cuyahoga Cty. Bd. of Elections, 74 Ohio St. 3d 143,
145, 656 N.E.2d 1277 (1995), the Ohio Supreme Court discussed the elements that are
required to be established for the equitable doctrine of laches to apply, stating: “The
elements of laches are (1) unreasonable delay or lapse of time in asserting a right,
(2) absence of an excuse for the delay, (3) knowledge, actual or constructive, of the
injury or wrong, and (4) prejudice to the other party. State ex rel. Meyers v. Columbus
Case No. 2017-00063                         -20-                                 DECISION

(1995), 71 Ohio St. 3d 603, 605, 646 N.E.2d 173, 174.” At least one Ohio appellate
court has suggested whether the doctrine of laches applies is subject to a court’s
discretion. See, e.g., State ex rel. Allied Sys. Holdings v. Donders, 10th Dist. Franklin
No. 11AP-960, 2012-Ohio-5855, ¶ 14 (“this court has consistently applied an abuse-of-
discretion standard in laches cases, including at least one case involving the Industrial
Commission”). But another Ohio appellate court has suggested whether the doctrine of
laches applies presents a question of law. See State ex rel. Doran v. Preble Cty. Bd. of
Commrs., 2013-Ohio-3579, 995 N.E.2d 239, ¶ 15 (12th Dist.) (“The issue is whether
Ohio law permits the equitable application of the doctrine of laches to claims regarding
the rights of taxpayers. As this is a question of law, we review appellants’ contention
under a de novo standard of review”). Notably, the Ohio Supreme Court has stated:
“Whether the four elements of laches are applicable is ultimately a factual
determination.” Hara v. Montgomery Cty. Joint Vocational Sch. Dist., 75 Ohio St. 3d 60,
64, 661 N.E.2d 711 (1996).
       {¶33} Here, in a related case decided on December 12, 2016—Colaianni Constr.
v. Indian Creek Local School Dist., 7th Dist. Jefferson No. 16 JE 0009, 2016-Ohio-
8156—the Seventh District Court of Appeals determined that claims pertaining to the
present case should be brought in this Court, stating: “As the public owner is the State
of Ohio, the remedy is not arbitration under R.C. 153.63(B).              To the contrary,
R.C. 153.63(C) directs the contractor to file an action in the court of claims. Accordingly,
the trial court should have dismissed the case for lack of jurisdiction instead of
compelling arbitration.” Colaianni Construction, ¶ 1. On January 19, 2017—about five
weeks after the Seventh District Court of Appeals issued Colaianni Construction—
Colaianni filed its original complaint in this Court. Viewing the evidence (i.e., Colaianni’s
pleadings, affidavits filed by the parties, and documents authenticated by affidavit) in
favor of Colaianni, as required by Civ.R. 56(C), the Court finds that under these
circumstances reasonable minds can come to but one conclusion—namely, that
Colaianni’s delay in filing its original complaint in this Court after the appellate court
Case No. 2017-00063                         -21-                                 DECISION

issued Colaianni Construction— does not present a genuine issue of material fact
whether Colaianni unreasonably delayed in asserting its rights in this Court.
       {¶34} The Court’s finding is supported by the parties’ contract.         The parties’
contract contains an alternative-dispute-resolution provision, G.C. 8.10, and the term
alternative dispute resolution, as used in the contract, may be construed to include
arbitration. See Definitions (defining alternative dispute resolution in the contract as a
“voluntary and non-binding process for the administrative review, consideration, and
attempted settlement of a dispute, without resort to judicial process including, without
limitation, partnering, negotiation, mediation, and impartial fact-finding, but not binding
arbitration or litigation”). Thus, a contractual basis existed for Colaianni’s decision to
seek the appointment of an arbitrator.       And until the appellate court rendered its
decision in December 2016, whether the common pleas court had jurisdiction to compel
arbitration had not been adjudicated by an appellate court of competent jurisdiction.
       {¶35} Moreover, because traditionally the equitable defense of laches has been
unavailable in actions at law brought within an applicable statute of limitations, see
Cornetta v. United States, 851 F.2d 1372, 1376 (Fed.Cir.1988); Baltimore Trust Co. v.
Norton Coal Mining Co., 25 F. Supp. 968, 971 (W.D.Ky.1939), and because, as
discussed above, whether Colaianni’s claims are time-barred presents a genuine issue
of material fact, the Court determines that Colaianni’s claims should not be barred by
the equitable doctrine of laches in this instance.
       {¶36} Finally, the Court considers OSFC’s contentions that Colaianni has not
stated an appropriate claim for declaratory relief; that Colaianni has not joined parties
statutorily required for this Court to consider such relief; and that Colaianni’s
declaratory-judgment claim is time-barred.
       {¶37} In Colaianni’s First Amended Complaint, Colaianni asserts that a
declaratory judgment “is required * * * to declare the parties’ respective rights, status
and other legal relations under the Contract and Contract Documents, including but not
limited to whether Colaianni has any responsibility to perform or pay for additional work
Case No. 2017-00063                         -22-                                 DECISION

on the parking lot.” (First Amended Complaint, ¶ 38.) Colaianni also asserts that it
“seeks declaratory judgment that the problems with the parking lot were proximately
caused by a design error of the OSFC’s agent, and not by any defective work by
Colaianni and/or its subcontractor, and further that Colaianni is not responsible for any
additional work on the parking lot as proposed by OSFC.” (First Amended Complaint,
¶ 39.)
         {¶38} A declaratory judgment is defined as a “binding adjudication that
establishes the rights and other legal relations of the parties without providing for or
ordering enforcement.” Black’s Law Dictionary 971 (10th Ed.2014). To the extent that
in Colaianni’s First Amended Complaint Colaianni seeks a declaration about the rights
and legal relations of itself and OSFC under the parties’ contract, the Court determines
that Colaianni has asserted a proper declaratory-judgment claim. But to the extent that
in its declaratory-judgment claim Colaianni seeks a determination about the proximate
cause for problems with the project’s parking lot or an order of enforcement pertaining
to Colaianni’s breach-of-contract claim, the Court concludes that Colaianni’s
declaratory-judgment claim is not a proper declaratory-judgment claim.
         {¶39} R.C. 2743.03(A)(2) grants authority to this Court to consider a claim for a
declaratory judgment in certain circumstances. According to R.C. 2743.03(A)(2), if the
claimant in a civil action as described in R.C. 2743.03(A)(1) “also files a claim for a
declaratory judgment * * * against the state that arises out of the same circumstances
that gave rise to the civil action described in division (A)(1) of this section, the court of
claims has exclusive, original jurisdiction to hear and determine that claim in that civil
action.” Thus, to the extent that Colaianni has asserted a proper declaratory-judgment
claim against OSFC that arises out of the same circumstances that gives rise to
Colaianni’s breach-of-contract claim against OSFC, the Court finds that Colaianni’s
declaratory-judgment claim is properly before the Court in accordance with
R.C. 2743.03 (A)(2). As to OSFC’s suggestion that other parties, namely, the project’s
architect, the school district, and Colaianni’s subcontractor, are potentially affected by
Case No. 2017-00063                        -23-                                DECISION

this Court’s determination of Colaianni’s declaratory-judgment claim and therefore
should be made parties to this case pursuant to R.C. 2721.12, the Court finds OSFC’s
argument is unpersuasive.        In the Court’s view, the relevant statute governing
Colaianni’s declaratory-judgment claim is R.C. 2743.03(A)(2)—not R.C. 2721.12.
Moreover, because, as a matter of law, only the state may be a defendant in original
actions before this Court, see Rooney v. Ohio State Highway Patrol, 10th Dist. Franklin
No. 16AP-204, 2017-Ohio-1123, ¶ 5, Colaianni is, as a matter of law, precluded from
bringing a declaratory-judgment claim in this Court against the project’s architect, school
district, and Colaianni’s subcontractor.
       {¶40} Also, in the Court’s view, the declaratory-judgment claim, as pleaded by
Colaianni, effectively is a breach-of-contract claim. See Ambulatory Care Affiliates, Ltd.
v. OhioHealth Corp., 10th Dist. Franklin No. 10AP-30, 2010-Ohio-3035, ¶ 10 (actions for
declaratory judgment are special proceedings but when a declaratory judgment claim is
asserted within the context of an ordinary civil action for breach of contract, the
underlying action governs an appellate court’s analysis). Because, as discussed above,
the Court has determined that a trier-of-fact could conclude that a genuine issue of
material fact exists as to whether Colaianni’s breach-of-contract claim is time-barred, it
follows that a genuine issue of material fact exists as to whether Colaianni’s proper
declaratory-judgment claim, which arises from the same circumstances as the breach-
of-contract claim, is time-barred.

   V. Conclusion
       {¶41} Accordingly, for reasons set forth above, the Referee recommends that
OSFC’s motion to dismiss and alternative motion of February 16, 2017 should be
denied, that OSFC’s motion to dismiss and OSFC’s alternative motion of March 16,
2017 should be construed as a motion for summary judgment and should be denied,
and that OSFC’s motion to strike filed on April 20, 2017 should be denied.
Case No. 2017-00063                         -24-                                DECISION

        {¶42} Pursuant to R.C. 2743.03(C), proceedings governing referees “shall be in
accordance with Civil Rule 53, except as modified by this division.”          According to
Civ.R. 53(D)(3)(b)(i), a party may file written objections to a magistrate’s decision within
14 days of the filing of the decision, whether or not the court has adopted the decision
during that 14-day period as permitted by Civ.R. 53(D)(4)(e)(i). If any party timely files
objections, any other party may also file objections not later than ten days after the first
objections are filed. A party shall not assign as error on appeal the court’s adoption of
any factual finding or legal conclusion, whether or not specifically designated as a
finding of fact or conclusion of law under Civ.R. 53(D)(3)(a)(ii), unless the party timely
and specifically objects to that factual finding or legal conclusion within 14 days of the
filing of the decision, as required by Civ.R. 53(D)(3)(b).

                                                DALE A. CRAWFORD
                                                Referee

cc:
Donald W. Gregory                             David A. Beals
Michael J. Madigan                            James E. Rook
Timothy A. Kelley                             Assistant Attorneys General
Capitol Square Office Building                150 East Gay Street, 18th Floor
65 East State Street, Suite 1800              Columbus, Ohio 43215-3130
Columbus, Ohio 43215-4294

Filed July 7, 2017
Sent to S.C. Reporter 8/9/17