Source: http://lawlibrary.chanrobles.com/index.php?option=com_content&amp;view=article&amp;id=45865:146717&amp;catid=1459&amp;Itemid=566
Timestamp: 2019-04-19 18:41:50+00:00

Document:
TRANSFIELD PHILIPPINES, INC., Petitioner, v. LUZON HYDRO CORPORATION, AUSTRALIA and NEW ZEALAND BANKING GROUP LIMITED and SECURITY BANK CORPORATION, Respondents.
Subject of this case is the letter of credit which has evolved as the ubiquitous and most important device in international trade. A creation of commerce and businessmen, the letter of credit is also unique in the number of parties involved and its supranational character.
In the course of the construction of the project, petitioner sought various EOT to complete the Project. The extensions were requested allegedly due to several factors which prevented the completion of the Project on target date, such as force majeure occasioned by typhoon Zeb, barricades and demonstrations. LHC denied the requests, however. This gave rise to a series of legal actions between the parties which culminated in the instant petition.
The first of the actions was a Request for Arbitration which LHC filed before the Construction Industry Arbitration Commission (CIAC) on 1 June 1999.10 This was followed by another Request for Arbitration, this time filed by petitioner before the International Chamber of Commerce (ICC)11 on 3 November 2000. In both arbitration proceedings, the common issues presented were: [1) whether typhoon Zeb and any of its associated events constituted force majeure to justify the extension of time sought by petitioner; and [2) whether LHC had the right to terminate the Turnkey Contract for failure of petitioner to complete the Project on target date.
Meanwhile, foreseeing that LHC would call on the Securities pursuant to the pertinent provisions of the Turnkey Contract,12 petitioner in two separate letters13 both dated 10 August 2000 advised respondent banks of the arbitration proceedings already pending before the CIAC and ICC in connection with its alleged default in the performance of its obligations. Asserting that LHC had no right to call on the Securities until the resolution of disputes before the arbitral tribunals, petitioner warned respondent banks that any transfer, release, or disposition of the Securities in favor of LHC or any person claiming under LHC would constrain it to hold respondent banks liable for liquidated damages.
On 5 November 2000, petitioner as plaintiff filed a Complaint for Injunction, with prayer for temporary restraining order and writ of preliminary injunction, against herein respondents as defendants before the Regional Trial Court (RTC) of Makati.17 Petitioner sought to restrain respondent LHC from calling on the Securities and respondent banks from transferring, paying on, or in any manner disposing of the Securities or any renewals or substitutes thereof. The RTC issued a seventy-two (72)-hour temporary restraining order on the same day. The case was docketed as Civil Case No. 00-1312 and raffled to Branch 148 of the RTC of Makati.
The RTC, in its Order19 dated 24 November 2000, denied petitioner's application for a writ of preliminary injunction. It ruled that petitioner had no legal right and suffered no irreparable injury to justify the issuance of the writ. Employing the principle of "independent contract" in letters of credit, the trial court ruled that LHC should be allowed to draw on the Securities for liquidated damages. It debunked petitioner's contention that the principle of "independent contract" could be invoked only by respondent banks since according to it respondent LHC is the ultimate beneficiary of the Securities. The trial court further ruled that the banks were mere custodians of the funds and as such they were obligated to transfer the same to the beneficiary for as long as the latter could submit the required certification of its claims.
Dissatisfied with the trial court's denial of its application for a writ of preliminary injunction, petitioner elevated the case to the Court of Appeals via a Petition for Certiorari under Rule 65, with prayer for the issuance of a temporary restraining order and writ of preliminary injunction.20 Petitioner submitted to the appellate court that LHC's call on the Securities was premature considering that the issue of its default had not yet been resolved with finality by the CIAC and/or the ICC. It asserted that until the fact of delay could be established, LHC had no right to draw on the Securities for liquidated damages.
Refuting petitioner's contentions, LHC claimed that petitioner had no right to restrain its call on and use of the Securities as payment for liquidated damages. It averred that the Securities are independent of the main contract between them as shown on the face of the two Standby Letters of Credit which both provide that the banks have no responsibility to investigate the authenticity or accuracy of the certificates or the declarant's capacity or entitlement to so certify.
In its Resolution dated 28 November 2000, the Court of Appeals issued a temporary restraining order, enjoining LHC from calling on the Securities or any renewals or substitutes thereof and ordering respondent banks to cease and desist from transferring, paying or in any manner disposing of the Securities.
However, the appellate court failed to act on the application for preliminary injunction until the temporary restraining order expired on 27 January 2001. Immediately thereafter, representatives of LHC trooped to ANZ Bank and withdrew the total amount of US$4,950,000.00, thereby reducing the balance in ANZ Bank to US$1,852,814.00.
On 2 February 2001, the appellate court dismissed the petition for certiorari . The appellate court expressed conformity with the trial court's decision that LHC could call on the Securities pursuant to the first principle in credit law that the credit itself is independent of the underlying transaction and that as long as the beneficiary complied with the credit, it was of no moment that he had not complied with the underlying contract. Further, the appellate court held that even assuming that the trial court's denial of petitioner's application for a writ of preliminary injunction was erroneous, it constituted only an error of judgment which is not correctible by certiorari , unlike error of jurisdiction.
WHETHER THE "INDEPENDENCE PRINCIPLE" ON LETTERS OF CREDIT MAY BE INVOKED BY A BENEFICIARY THEREOF WHERE THE BENEFICIARY'S CALL THEREON IS WRONGFUL OR FRAUDULENT.
WHETHER LHC HAS THE RIGHT TO CALL AND DRAW ON THE SECURITIES BEFORE THE RESOLUTION OF PETITIONER'S AND LHC'S DISPUTES BY THE APPROPRIATE TRIBUNAL.
WHETHER ANZ BANK AND SECURITY BANK ARE JUSTIFIED IN RELEASING THE AMOUNTS DUE UNDER THE SECURITIES DESPITE BEING NOTIFIED THAT LHC'S CALL THEREON IS WRONGFUL.
A. LHC IS ALLOWED TO CALL AND DRAW ON, AND ANZ BANK AND SECURITY BANK ARE ALLOWED TO RELEASE, THE REMAINING BALANCE OF THE SECURITIES PRIOR TO THE RESOLUTION OF THE DISPUTES BETWEEN PETITIONER AND LHC.
Petitioner contends that the courts below improperly relied on the "independence principle" on letters of credit when this case falls squarely within the "fraud exception rule." Respondent LHC deliberately misrepresented the supposed existence of delay despite its knowledge that the issue was still pending arbitration, petitioner continues.
Petitioner asserts that LHC should be ordered to return the proceeds of the Securities pursuant to the principle against unjust enrichment and that, under the premises, injunction was the appropriate remedy obtainable from the competent local courts.
On 25 August 2003, petitioner filed a Supplement to the Petition22 and Supplemental Memorandum,23 alleging that in the course of the proceedings in the ICC Arbitration, a number of documentary and testimonial evidence came out through the use of different modes of discovery available in the ICC Arbitration. It contends that after the filing of the petition facts and admissions were discovered which demonstrate that LHC knowingly misrepresented that petitioner had incurred delays' notwithstanding its knowledge and admission that delays were excused under the Turnkey Contract to be able to draw against the Securities. Reiterating that fraud constitutes an exception to the independence principle, petitioner urges that this warrants a ruling from this Court that the call on the Securities was wrongful, as well as contrary to law and basic principles of equity. It avers that it would suffer grave irreparable damage if LHC would be allowed to use the proceeds of the Securities and not ordered to return the amounts it had wrongfully drawn thereon.
In its Manifestation dated 8 September 2003,24 LHC contends that the supplemental pleadings filed by petitioner present erroneous and misleading information which would change petitioner's theory on appeal.
In yet another Manifestation dated 12 April 2004,25 petitioner alleges that on 18 February 2004, the ICC handed down its Third Partial Award, declaring that LHC wrongfully drew upon the Securities and that petitioner was entitled to the return of the sums wrongfully taken by LHC for liquidated damages.
LHC filed a Counter-Manifestation dated 29 June 2004,26 stating that petitioner's Manifestation dated 12 April 2004 enlarges the scope of its Petition for Review of the 31 January 2001 Decision of the Court of Appeals. LHC notes that the Petition for Review essentially dealt only with the issue of whether injunction could issue to restrain the beneficiary of an irrevocable letter of credit from drawing thereon. It adds that petitioner has filed two other proceedings, to wit: (1) ICC Case No. 11264/TE/MW, entitled "Transfield Philippines Inc. v. Luzon Hydro Corporation," in which the parties made claims and counterclaims arising from petitioner's performance/misperformance of its obligations as contractor for LHC; and (2) Civil Case No. 04-332, entitled "Transfield Philippines, Inc. v. Luzon Hydro Corporation" before Branch 56 of the RTC of Makati, which is an action to enforce and obtain execution of the ICC's partial award mentioned in petitioner's Manifestation of 12 April 2004.
In its Comment to petitioner's Motion for Leave to File Addendum to Petitioner's Memorandum, LHC stresses that the question of whether the funds it drew on the subject letters of credit should be returned is outside the issue in this appeal. At any rate, LHC adds that the action to enforce the ICC's partial award is now fully within the Makati RTC's jurisdiction in Civil Case No. 04-332. LHC asserts that petitioner is engaged in forum-shopping by keeping this appeal and at the same time seeking the suit for enforcement of the arbitral award before the Makati court.
Respondent SBC in its Memorandum, dated 10 March 200327 contends that the Court of Appeals correctly dismissed the petition for certiorari . Invoking the independence principle, SBC argues that it was under no obligation to look into the validity or accuracy of the certification submitted by respondent LHC or into the latter's capacity or entitlement to so certify. It adds that the act sought to be enjoined by petitioner was already fait accompli and the present petition would no longer serve any remedial purpose.
In a similar fashion, respondent ANZ Bank in its Memorandum dated 13 March 200328 posits that its actions could not be regarded as unjustified in view of the prevailing independence principle under which it had no obligation to ascertain the truth of LHC's allegations that petitioner defaulted in its obligations. Moreover, it points out that since the Standby Letter of Credit No. E001126/8400 had been fully drawn, petitioner's prayer for preliminary injunction had been rendered moot and academic.
At the core of the present controversy is the applicability of the "independence principle" and "fraud exception rule" in letters of credit. Thus, a discussion of the nature and use of letters of credit, also referred to simply as "credits," would provide a better perspective of the case.
In Bank of the Philippine Islands v. De Reny Fabric Industries, Inc.,37 this Court ruled that the observance of the UCP is justified by Article 2 of the Code of Commerce which provides that in the absence of any particular provision in the Code of Commerce, commercial transactions shall be governed by usages and customs generally observed. More recently, in Bank of America, NT & SA v. Court of Appeals,38 this Court ruled that there being no specific provisions which govern the legal complexities arising from transactions involving letters of credit, not only between or among banks themselves but also between banks and the seller or the buyer, as the case may be, the applicability of the UCP is undeniable.
Article 3 of the UCP provides that credits, by their nature, are separate transactions from the sales or other contract(s) on which they may be based and banks are in no way concerned with or bound by such contract(s), even if any reference whatsoever to such contract(s) is included in the credit. Consequently, the undertaking of a bank to pay, accept and pay draft(s) or negotiate and/or fulfill any other obligation under the credit is not subject to claims or defenses by the applicant resulting from his relationships with the issuing bank or the beneficiary. A beneficiary can in no case avail himself of the contractual relationships existing between the banks or between the applicant and the issuing bank.
Petitioner insists that the independence principle does not apply to the instant case and assuming it is so, it is a defense available only to respondent banks. LHC, on the other hand, contends that it would be contrary to common sense to deny the benefit of an independent contract to the very party for whom the benefit is intended. As beneficiary of the letter of credit, LHC asserts it is entitled to invoke the principle.
As discussed above, in a letter of credit transaction, such as in this case, where the credit is stipulated as irrevocable, there is a definite undertaking by the issuing bank to pay the beneficiary provided that the stipulated documents are presented and the conditions of the credit are complied with.41 Precisely, the independence principle liberates the issuing bank from the duty of ascertaining compliance by the parties in the main contract. As the principle's nomenclature clearly suggests, the obligation under the letter of credit is independent of the related and originating contract. In brief, the letter of credit is separate and distinct from the underlying transaction.
Given the nature of letters of credit, petitioner's argument that it is only the issuing bank that may invoke the independence principle on letters of credit does not impress this Court. To say that the independence principle may only be invoked by the issuing banks would render nugatory the purpose for which the letters of credit are used in commercial transactions. As it is, the independence doctrine works to the benefit of both the issuing bank and the beneficiary.
Letters of credit are employed by the parties desiring to enter into commercial transactions, not for the benefit of the issuing bank but mainly for the benefit of the parties to the original transactions. With the letter of credit from the issuing bank, the party who applied for and obtained it may confidently present the letter of credit to the beneficiary as a security to convince the beneficiary to enter into the business transaction. On the other hand, the other party to the business transaction, i.e., the beneficiary of the letter of credit, can be rest assured of being empowered to call on the letter of credit as a security in case the commercial transaction does not push through, or the applicant fails to perform his part of the transaction. It is for this reason that the party who is entitled to the proceeds of the letter of credit is appropriately called "beneficiary."
Petitioner's argument that any dispute must first be resolved by the parties, whether through negotiations or arbitration, before the beneficiary is entitled to call on the letter of credit in essence would convert the letter of credit into a mere guarantee. Jurisprudence has laid down a clear distinction between a letter of credit and a guarantee in that the settlement of a dispute between the parties is not a pre-requisite for the release of funds under a letter of credit. In other words, the argument is incompatible with the very nature of the letter of credit. If a letter of credit is drawable only after settlement of the dispute on the contract entered into by the applicant and the beneficiary, there would be no practical and beneficial use for letters of credit in commercial transactions.
The standby credit is an attractive commercial device for many of the same reasons that commercial credits are attractive. Essentially, these credits are inexpensive and efficient. Often they replace surety contracts, which tend to generate higher costs than credits do and are usually triggered by a factual determination rather than by the examination of documents.
Because parties and courts should not confuse the different functions of the surety contract on the one hand and the standby credit on the other, the distinction between surety contracts and credits merits some reflection. The two commercial devices share a common purpose. Both ensure against the obligor's nonperformance. They function, however, in distinctly different ways.
Traditionally, upon the obligor's default, the surety undertakes to complete the obligor's performance, usually by hiring someone to complete that performance. Surety contracts, then, often involve costs of determining whether the obligor defaulted (a matter over which the surety and the beneficiary often litigate) plus the cost of performance. The benefit of the surety contract to the beneficiary is obvious. He knows that the surety, often an insurance company, is a strong financial institution that will perform if the obligor does not. The beneficiary also should understand that such performance must await the sometimes lengthy and costly determination that the obligor has defaulted. In addition, the surety's performance takes time.
The standby credit has different expectations. He reasonably expects that he will receive cash in the event of nonperformance, that he will receive it promptly, and that he will receive it before any litigation with the obligor (the applicant) over the nature of the applicant's performance takes place. The standby credit has this opposite effect of the surety contract: it reverses the financial burden of parties during litigation.
In the surety contract setting, there is no duty to indemnify the beneficiary until the beneficiary establishes the fact of the obligor's performance. The beneficiary may have to establish that fact in litigation. During the litigation, the surety holds the money and the beneficiary bears most of the cost of delay in performance.
While it is the bank which is bound to honor the credit, it is the beneficiary who has the right to ask the bank to honor the credit by allowing him to draw thereon. The situation itself emasculates petitioner's posture that LHC cannot invoke the independence principle and highlights its puerility, more so in this case where the banks concerned were impleaded as parties by petitioner itself.
8.7.1 If the Contractor fails to comply with Clause 8.2, the Contractor shall pay to the Employer by way of liquidated damages ("Liquidated Damages for Delay") the amount of US$75,000 for each and every day or part of a day that shall elapse between the Target Completion Date and the Completion Date, provided that Liquidated Damages for Delay payable by the Contractor shall in the aggregate not exceed 20% of the Contract Price. The Contractor shall pay Liquidated Damages for Delay for each day of the delay on the following day without need of demand from the Employer.
A contract once perfected, binds the parties not only to the fulfillment of what has been expressly stipulated but also to all the consequences which according to their nature, may be in keeping with good faith, usage, and law.46 A careful perusal of the Turnkey Contract reveals the intention of the parties to make the Securities answerable for the liquidated damages occasioned by any delay on the part of petitioner. The call upon the Securities, while not an exclusive remedy on the part of LHC, is certainly an alternative recourse available to it upon the happening of the contingency for which the Securities have been proffered. Thus, even without the use of the "independence principle," the Turnkey Contract itself bestows upon LHC the right to call on the Securities in the event of default.
Next, petitioner invokes the "fraud exception" principle. It avers that LHC's call on the Securities is wrongful because it fraudulently misrepresented to ANZ Bank and SBC that there is already a breach in the Turnkey Contract knowing fully well that this is yet to be determined by the arbitral tribunals. It asserts that the "fraud exception" exists when the beneficiary, for the purpose of drawing on the credit, fraudulently presents to the confirming bank, documents that contain, expressly or by implication, material representations of fact that to his knowledge are untrue. In such a situation, petitioner insists, injunction is recognized as a remedy available to it.
Citing Dolan's treatise on letters of credit, petitioner argues that the independence principle is not without limits and it is important to fashion those limits in light of the principle's purpose, which is to serve the commercial function of the credit. If it does not serve those functions, application of the principle is not warranted, and the commonlaw principles of contract should apply.
The pendency of the arbitration proceedings would not per se make LHC's draws on the Securities wrongful or fraudulent for there was nothing in the Contract which would indicate that the parties intended that all disputes regarding delay should first be settled through arbitration before LHC would be allowed to call upon the Securities. It is therefore premature and absurd to conclude that the draws on the Securities were outright fraudulent given the fact that the ICC and CIAC have not ruled with finality on the existence of default.
Nowhere in its complaint before the trial court or in its pleadings filed before the appellate court, did petitioner invoke the fraud exception rule as a ground to justify the issuance of an injunction.58 What petitioner did assert before the courts below was the fact that LHC's draws on the Securities would be premature and without basis in view of the pending disputes between them. Petitioner should not be allowed in this instance to bring into play the fraud exception rule to sustain its claim for the issuance of an injunctive relief. Matters, theories or arguments not brought out in the proceedings below will ordinarily not be considered by a reviewing court as they cannot be raised for the first time on appeal.59 The lower courts could thus not be faulted for not applying the fraud exception rule not only because the existence of fraud was fundamentally interwoven with the issue of default still pending before the arbitral tribunals, but more so, because petitioner never raised it as an issue in its pleadings filed in the courts below. At any rate, petitioner utterly failed to show that it had a clear and unmistakable right to prevent LHC's call upon the Securities.
Of course, prudence should have impelled LHC to await resolution of the pending issues before the arbitral tribunals prior to taking action to enforce the Securities. But, as earlier stated, the Turnkey Contract did not require LHC to do so and, therefore, it was merely enforcing its rights in accordance with the tenor thereof. Obligations arising from contracts have the force of law between the contracting parties and should be complied with in good faith.60 More importantly, pursuant to the principle of autonomy of contracts embodied in Article 1306 of the Civil Code,61 petitioner could have incorporated in its Contract with LHC, a proviso that only the final determination by the arbitral tribunals that default had occurred would justify the enforcement of the Securities. However, the fact is petitioner did not do so; hence, it would have to live with its inaction.
With respect to the issue of whether the respondent banks were justified in releasing the amounts due under the Securities, this Court reiterates that pursuant to the independence principle the banks were under no obligation to determine the veracity of LHC's certification that default has occurred. Neither were they bound by petitioner's declaration that LHC's call thereon was wrongful. To repeat, respondent banks' undertaking was simply to pay once the required documents are presented by the beneficiary.
At any rate, should petitioner finally prove in the pending arbitration proceedings that LHC's draws upon the Securities were wrongful due to the non-existence of the fact of default, its right to seek indemnification for damages it suffered would not normally be foreclosed pursuant to general principles of law.
Moreover, in a Manifestation,62 dated 30 March 2001, LHC informed this Court that the subject letters of credit had been fully drawn. This fact alone would have been sufficient reason to dismiss the instant petition.
Settled is the rule that injunction would not lie where the acts sought to be enjoined have already become fait accompli or an accomplished or consummated act.63 In Ticzon v. Video Post Manila, Inc.64 this Court ruled that where the period within which the former employees were prohibited from engaging in or working for an enterprise that competed with their former employer the very purpose of the preliminary injunction 'has expired, any declaration upholding the propriety of the writ would be entirely useless as there would be no actual case or controversy between the parties insofar as the preliminary injunction is concerned.
In the instant case, the consummation of the act sought to be restrained had rendered the instant petition moot for any declaration by this Court as to propriety or impropriety of the non-issuance of injunctive relief could have no practical effect on the existing controversy.65 The other issues raised by petitioner particularly with respect to its right to recover the amounts wrongfully drawn on the Securities, according to it, could properly be threshed out in a separate proceeding.
One final point. LHC has charged petitioner of forum-shopping. It raised the charge on two occasions. First, in its Counter-Manifestation dated 29 June 200466 LHC alleges that petitioner presented before this Court the same claim for money which it has filed in two other proceedings, to wit: ICC Case No. 11264/TE/MW and Civil Case No. 04-332 before the RTC of Makati. LHC argues that petitioner's acts constitutes forum-shopping which should be punished by the dismissal of the claim in both forums. Second, in its Comment to Petitioner's Motion for Leave to File Addendum to Petitioner's Memorandum dated 8 October 2004, LHC alleges that by maintaining the present appeal and at the same time pursuing Civil Case No. 04-332 wherein petitioner pressed for judgment on the issue of whether the funds LHC drew on the Securities should be returned petitioner resorted to forum-shopping. In both instances, however, petitioner has apparently opted not to respond to the charge.
Considering the seriousness of the charge of forum-shopping and the severity of the sanctions for its violation, the Court will refrain from making any definitive ruling on this issue until after petitioner has been given ample opportunity to respond to the charge.
WHEREFORE, the instant petition is DENIED, with costs against petitioner.
Petitioner is hereby required to answer the charge of forum-shopping within fifteen (15) days from notice.
1 Penned by Justice Candido V. Rivera, concurred in by Justices Conchita Carpio-Morales and Rebecca de Guia-Salvador.
5 Clause 1.1, Volume II of the Turnkey Contract, Rollo, p. 81.
7 Annex "C," Rollo, pp. 254-256.
8 Annex "D," Id. at 257-259.
9 Clause 4.2.1, Volume II of the Turnkey Contract, Id. at 94.
12 Turnkey Contract, Clause 4.2.5, Rollo, p. 94, in relation to Clause 8.7.1., Rollo, p. 132.
13 Annex "H," Rollo, pp. 287-289; Annex "H-1," Rollo, pp. 320-322.
14 Clause 8.2. Time for Completion.
15 Vol. 1, Rollo, pp. 355-357.
16 8.7.1. If the Contractor fails to comply with Clause 8.2, the Contractor shall pay to the Employer by way of liquidated damages ("Liquidated Damages for Delay") the amount of US$75,000 for each and every day or part of a day that shall elapse between the Target Completion Date and the Completion Date, provided that Liquidated Damages for Delay payable by the Contractor shall in the aggregate not exceed 20% of the Contract Price. The Contractor shall pay Liquidated Damages for Delay for each day of the delay on the following day without need of demand from the Employer.
17 Annex "L," Rollo, pp. 383-402.
18 Annex "N," Id. at 406-409.
19 Annex "O," Id. at 412-423.
20 Docketed as CA-G.R. SP No. 61901.
22 Vol. II; Id. at 2-78.
29 Joseph, Letters of Credit: The Developing Concepts and Financing Functions, 94 Banking Law Journal 850-851  cited in M. Kurkela, Letters of Credit under International Trade Law, 321 (1985).
30 Bank of America v. Court of Appeals, G.R. No. 105395, 10 December 1993, 228 SCRA 357 citing William S. Shaterian, Export-Import Banking: The Instruments and Operations Utilized by American Exporters and Importers and Their Banks in Financing Foreign Trade, 284-374 (1947).
31 E&H Partners v. Broadway Nat'l Bank, 39 F. Supp. 2d 275, (United States Circuit Court, S.D. New York) No. 96 Civ. 7098 (RLC), 19 October 1998 <http://www.westlaw.com>.
32 J. Dolan, The Law of Letters of Credit, Revised Ed. (2000).
33 24 A Words and Phrases 590, Permanent Edition.
35 Jackson & Davey, International Economic Relations, 53 (2nd ed.).
36 ICC Publication No. 500.
37 146 Phil. 269 (1970).
38 G.R. No. 105395, 10 December 1993, 228 SCRA 357.
40 Kurkela, Letters of Credit Under International Trade Law, 286-287 (1985).
42 Supra note 32 at 1-27.
43 Rollo, pp. 604 and 624.
44 Underscoring supplied; Id. at 94.
45 Underscoring supplied; Id. at 132.
46 Art. 1315, Civil Code.
47 Clause 20.4.1, Turnkey Contract, Rollo, p. 179.
48 Supra note 32 at 2-63.
49 M. Kurkela, Letters of Credit Under International Trade Law, 309 (1985).
51 Batangas Laguna Tayabas Bus Company, Inc. v. Bitanga, 415 Phil. 43.
52 Shin v. Court of Appeals, G.R. No. 113627, 6 February 2001, 351 SCRA 257.
53 Zabat v. Court of Appeals, G.R. No. 122089, 23 August 2000, 338 SCRA 551; Philippine Economic Zone Authority v. Vianzon, G.R. No. 131020, 20 July 2000, 336 SCRA 309; Valencia v. Court of Appeals, G.R. No. 119118, 19 February 2001, 352 SCRA 72; Crystal v. Cebu International School, G.R. No. 135433, 4 April 2001, 356 SCRA 296; Ong Ching Kian Chuan v. Court of Appeals, 415 Phil. 365 (2001).
54 Philippine National Bank v. Ritratto Group, Inc., 414 Phil. 494 (2001).
56 Underscoring supplied; Id. at 94-95.
58 Vide Annex "L," Rollo. pp. 392-399; Petition for Certiorari, CA Rollo, pp. 7-43.
59 Salafranca v. Philamlife Village Homeowners Association, Inc., 360 Phil. 652; Ruby Industrial Corporation v. Court of Appeals, 348 Phil. 480; Victorias Milling Co., Inc. v. Court of Appeals, 389 Phil. 184.
60 Article 1159, Civil Code.
61 Art. 1306. The contracting parties may establish such stipulations, clauses, terms and conditions as they may deem convenient, provided they are not contrary to law, morals, good customs, public order, or public policy.
63 Aznar Brothers Realty Company v. Court of Appeals, G.R. No. 128102, 7 March 2000, 327 SCRA 359; Soriano v. Court of Appeals, 416 Phil. 226 (2001); Rodil Enterprises v. Court of Appeals, G.R. No. G.R. No. 129609, 29 November 2001, 371 SCRA 79; Unionbank of the Philippines v. Court of Appeals, 370 Phil. 837 (1999).
64 389 Phil. 20 (2000).
65 Black's Law Dictionary, p. 1008, citing Leonhart v. McCormick, D.C. Pa., 395 F. Supp. 1073.
66 Vol. II, Rollo, pp. 666-669.
67 Tantoy, Sr. v. Court of Appeals, G.R. No. 141427, April 20, 2001, 357 SCRA 329.
68 Bangko Silangan Development Bank v. Court of Appeals, 412 Phil. 755 (2001).
69 Tirona v. Alejo, G.R. No. 129313, October 10, 2001, 367 SCRA 17; Manalo v. Court of Appeals, G.R. No. 141297, October 8, 2001, 366 SCRA 752.
70 Tantoy, Sr. v. Court of Appeals, supra note 67.; Caviles v. Seventeenth Division, Court of Appeals, G.R. No. 126857, September 18, 2002, 389 SCRA 306.

References: v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 V. 
 v. 
 v. 
 Art. 1315
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 Art. 1306
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v. 
 v.