Source: https://www.docusign.com/company/terms-and-conditions/appliance/v161001
Timestamp: 2019-04-25 12:25:02+00:00

Document:
“Authorized User” means any employee or agent of Customer that has been issued a unique signing or key credential that can be authenticated by the Appliance Subscription Service under the Customer’s user-management policy.
“Key Operation” means data associated with a key-usage request, including data encryption or decryption requests, hash value, associated application, and User’s identifying information under the Customer’s user-management policy and successful fulfillment of that request by the Appliance Subscription Service.
“Order Form” means the schedule that sets forth the pricing, features and options of the Appliance Subscription Service(s) selected by Customer. An Order Form is not binding until it is duly executed by both DocuSign and Customer, at which point it becomes incorporated into and part of the Agreement.
“Professional Services” means any integration consulting or assistance, training, transition and similar ancillary services that are set forth in an Order Form or Statement of Work as described in Section 11 through14.
“Seat” means an Authorized User activated to use the Appliance Subscription Service. Customer may unregister or deactivate Authorized Users and replace them with other Authorized Users without penalty, so long as the number of active Authorized Users registered at any one time is equal to or less than the number of Seats subscribed.
2.2 Customer may not cancel any order due to delay in delivery unless it (i) first provides DocuSign with written notice of the delay and its intent to cancel, and (ii) allows DocuSign an opportunity to complete shipment within sixty (60) days following receipt of Customer’s notice. DocuSign shall not be liable for any damages or penalty for delay in delivery or for failure to give notice of delay for any reason whatsoever.
2.3 Post-Termination Obligations. If this Agreement expires or is terminated for any reason: (a) Customer will pay to DocuSign any amounts that have accrued before, and remain unpaid as of, the date of the termination or expiration; (b) any and all liabilities of Customer to DocuSign that have accrued before the effective date of the termination will survive; (c) licenses and use rights granted to Customer with respect to Appliance Subscription Service(s) and intellectual property will immediately terminate; (d) DocuSign’s obligation to provide any further services to Customer under this Agreement will immediately terminate; (e) Customer shall return or destroy, as DocuSign may direct, any and/or all Software, Documentation, and Developer Bundle and if so requested by DocuSign, deliver to DocuSign a certificate executed by one of its duly authorized officers confirming compliance with the return or destruction obligation; and (f) the parties’ rights and obligations under Sections 1, 6.7, 8, 9, 10, 13 and 14 will survive together with those Sections as set forth Attachment 1. Upon termination of this Agreement by DocuSign for Customer’s uncured material breach of this Agreement, Customer will be responsible for any costs and expenses incurred by DocuSign to recover any Equipment, Software and/or Documentation. Upon termination of this Agreement by Customer for DocuSign’s uncured material breach of this Agreement, DocuSign will provide Customer with a prorated refund of prepaid subscription fees paid by Customer under the Order Form corresponding to the unused portion of the Term after the effective date of termination.
3.1 Invoicing. Customer will be invoiced as set forth in the Order Form. Unless otherwise specified in an applicable Order Form, the first invoice will coincide with the Order Start Date and, unless otherwise agreed by the parties in writing, all amounts will be denominated in U.S. dollars. DocuSign may assess finance charges equal to the lesser of 1.5% of the unpaid balance per month or the highest rate permitted by applicable usury law. Customer will be responsible for any reasonable attorneys’ fees, costs and expenses incurred by DocuSign to collect any amounts that are not paid when due.
4. SUBSCRIPTION PLANS AND USAGE PRICING. Appliance Subscription Service(s) is sold on the basis of an annual prepaid subscription, and may be limited by number of Signatures, Authorized User, Seat or other metrics or usage limitations as set forth in the Order Form.
5.1 Delivery of Equipment. Delivery of Equipment will be FCA Origin, Incoterms 2010. Unless otherwise specified in an applicable Order Form, during the subscription Term DocuSign will pay the freight for transportation of Equipment to Customer. Title transfers and Customer assumes all risk of loss upon delivery of the Equipment by DocuSign to a carrier at DocuSign’s premises. DocuSign will select the carrier but shall not be deemed thereby to assume any liability in connection with the shipment nor shall the carrier be an agent of DocuSign. Customer will be responsible for all storage drayage and other charges at Customer’s site.
5.2 DocuSign reserves the right, without prior approval from or notice to Customer, to make changes to Equipment (i) which do not adversely affect the performance of the Equipment or do not reduce performance below any contractually agreed to specification; (ii) when required for purposes of safety; or (iii) to meet Equipment specifications. DocuSign also reserves the right to make improvements to the Equipment without incurring any obligation or liability to make the same changes in Equipment previously manufactured.
5.3 Provision of Appliance Subscription Services. Subject to the terms of this Agreement, Attachment 1 and the applicable licensing terms contained therein, DocuSign grants Customer a personal, non-exclusive, non-transferrable, revocable license to use the Equipment and Software to operate the Equipment in accordance with the Documentation. DocuSign will provide Appliance Subscription Service(s) in accordance with the Documentation. The right to use Appliance Subscription Service(s) is limited to the Authorized Users, and Customer may not resell Appliance Subscription Service(s) or use the Equipment with software other than the Software provided by DocuSign to Customer under this Agreement. DocuSign hereby grants to Customer for the Term a non-exclusive, non-transferable license to copy and use the object code versions of the Software that will accompany the Equipment, for the purposes of (i) integrating Appliance Subscription Service(s) with Customer’s Application, (ii) using Appliance Subscription Service(s) for Customer’s Application with Equipment, and (iii) supporting Appliance Subscription Service(s). No sublicensing rights are granted or implied. Title to the Appliance Subscription Service(s) Software shall at all times remain with DocuSign.
5.4 Customer Obligations. As a condition for this license, Customer shall (i) make all payments when due, (ii) grant DocuSign on-line access to the logs in Customer’s instance of the Appliance Subscription Service, (iii) cooperate with DocuSign’s requests to electronically monitor the number of Authorized Users, Seats and/or Signatures, and (iv) provide periodic reports in the form requested by DocuSign on Customer’s usage metrics.
5.5 Usage and Access Limitations. All Software license rights which are not expressly granted herein are deemed withheld. Without limitation on the foregoing, no rights to the DocuSign source code are granted or implied. Customer shall not: (i) adapt, alter, modify, translate, create derivative works of, reverse compile, disassemble, or otherwise attempt to reconstruct the source code of the Software; (ii) use the Software for any purpose that is not authorized in the Software documentation; (iii) allow use of the Software in any manner that allows internal access to its functionality other than through the functionality of the Customer’s systems that incorporate the Software or the Software’s interface (as the same may be enhanced from time to time) published by DocuSign; (iv) allow use of the Software to create digital signatures by any device other than the Equipment; (v) allow use of the Equipment with any software not approved by DocuSign; (vi) assign, pledge, rent, lease, loan or timeshare the Software to third parties; (vii) obfuscate, remove or alter any of the trademarks, trade names, logos, patent or copyright notices, confidential or proprietary rights notices or legends or other notices or markings on or in Appliance Subscription Service(s) or accompanying documentation, without DocuSign’s express written consent; (viii) add, or permit any third party to add, any markings, notices or legends to Appliance Subscription Service(s) without DocuSign’s express prior written consent; (ix) publish or otherwise disclose to any third party the results of any analysis, benchmark or other tests on Appliance Subscription Service(s); (x) copy any portion of the Software for any purpose not expressly allowed under this Agreement; (xi) sublicense or distribute the Software in any manner to any third party; or (xii) in the event the Customer’s Application is specifically identified in the Order Form, use the Software for any other application.
5.8 Intellectual Property Ownership, Copyright Protection. DocuSign and its licensors own various intellectual property and technology rights associated with the Appliance Subscription Service(s). Customer’s rights with respect to the foregoing are limited to the rights to use the Appliance Subscription Service(s) that are granted under this Agreement or the applicable Order Form for the purposes contemplated by this Agreement, and no other, and all rights not expressly granted are reserved by DocuSign and its licensors and suppliers. DocuSign does not license or transfer to Customer, or any Authorized User or other third party, any of DocuSign’s technology or other intellectual property rights. All right, title, and interest in and to DocuSign and its licensors’ technology and intellectual property, whether patent, copyright, trade secret, trademark, service mark, design, database or moral rights, remain solely with DocuSign and its licensors at all times. Without limiting the generality of the foregoing, the structure, organization and code of the Software are trade secrets and Confidential Information (as defined below) of DocuSign and its licensors. The Software is protected by law, including without limitation the copyright laws of the United States and other countries, and by international treaty provisions.
5.12 Technical Support. DocuSign will provide customer technical support to Customer in accordance with the Appliance Subscription Service and Technical Support plan that is identified on the Order Form, as further detailed in the Technical Support Agreement attached hereto as Attachment 2.
6.2 Equipment Warranty and Remedy. DocuSign’s limited Equipment warranty is in place for the subscription Term (“Equipment Warranty Period”). Under DocuSign’s limited Equipment warranty, DocuSign warrants against defects in workmanship and material for Equipment purchased from DocuSign or DocuSign-authorized reseller. DocuSign’s sole responsibility under this warranty shall be to either repair or replace, at its option, any component which fails during the applicable Equipment Warranty Period because of a defect in workmanship and material, provided Customer has promptly reported same to DocuSign in writing. All replaced broken or defective Equipment or parts shall become DocuSign’s property. DocuSign will honor the warranty at DocuSign’s repair facility. It is Customer’s responsibility to return, at its expense, the allegedly defective Equipment to DocuSign. Customer must obtain a Return Materials Authorization (RMA) number and shipping instructions from DocuSign prior to returning any Equipment under warranty. Transportation charges for the return of the Equipment to Customer within the states and territories of the United States shall be paid by DocuSign. For all other locations, the warranty excludes all costs of shipping, customs clearance and other related charges. If DocuSign determines that the Equipment is not defective within the terms of the warranty, Customer shall pay DocuSign all costs of handling, transportation and repairs at DocuSign’s then prevailing repair rates. All the above warranties are contingent upon proper use of the Equipment. These warranties will not apply (i) if adjustment, repair or parts replacement is required because of accident, unusual physical, electrical or electromagnetic stress, negligence of Customer, misuse, failure of electric power environmental controls, transportation, Equipment not maintained in accordance with DocuSign specifications, or abuses other than ordinary use; (ii) if the Equipment has been modified by Customer or has been repaired or altered outside DocuSign’s facilities, unless DocuSign specifically authorizes such repairs or alterations; or (iii) where DocuSign serial numbers, warranty data or quality assurance decals have been removed or altered. In no event shall DocuSign be liable for any breach of warranty in an amount exceeding the total amount payable by Customer to DocuSign under the Order Form to which the Appliance Subscription Service(s) relates. No person, including any dealer, agent or representative of DocuSign is authorized to assume for DocuSign any other liability on its behalf except as set forth herein. Non-payment of any invoice rendered within the payment terms of this Agreement automatically cancels any stated or implied warranty or guarantee.
7. INFRINGEMENT OF THIRD PARTY PROPRIETARY RIGHTS. If notified promptly in writing of any action (and all prior claims relating thereto) brought against Customer alleging that Customer's use of Appliance Subscription Service(s) infringes a United States patent, copyright or other proprietary right, DocuSign will defend such action at its expense and will pay the costs and damages awarded against Customer in such action, provided that (i) such claim of infringement arises solely from use of Appliance Subscription Service(s) itself, and not as a consequence of Appliance Subscription Service(s) in combination with any other products or technology, and (ii) DocuSign shall have sole control of the defense of any such action and all negotiations for its settlement or compromise. If a final injunction is obtained in such action against Customer's use of Appliance Subscription Service(s) or in DocuSign’s opinion Appliance Subscription Service(s) is likely to become the subject of a claim of infringement, DocuSign shall, at its option and expense, procure for Customer the right to continue using Appliance Subscription Service(s); replace or modify Appliance Subscription Service(s) so that it becomes non-infringing; or accept Customer's return of Equipment and cancellation of this Agreement. DocuSign shall not have any liability to Customer if the alleged infringement is based upon (a) DocuSign’s compliance with Customer's designs, specifications or instructions, in which case Customer shall defend and hold DocuSign harmless against any expenses, judgment or loss for alleged infringement of any patents, copyrights or trademarks; (b) patent issued on a patent application published after the Order Start Date; (c) incorporation by the Software or combination, operation or use of the Software in or with any technology (including any software, hardware, firmware, system or network) or service not provided by DocuSign or not specified for Customer’s use in the Documentation, unless otherwise expressly permitted by DocuSign in writing; (d) modification of the Software other than (1) by DocuSign in connection with this Agreement; or (2) with DocuSign’s express written authorization and in strict accordance with DocuSign’s written directions and specifications; (e) failure to timely implement any Update or Upgrade, modification, or replacement of the Software made available to Customer by DocuSign; (f) use of the Software after DocuSign’s notice to Customer of such activity's alleged or actual infringement, misappropriation or other violation of a third party's rights; (g) negligence, abuse, misapplication or misuse of the Software or Documentation by or on behalf of Customer, Customer’s representatives or a third party; (h) use of the Software or Documentation by or on behalf of Customer that is outside the purpose, scope or manner of use authorized by this Agreement or in any manner contrary to DocuSign’s instructions; or (i) events or circumstances outside of DocuSign’s commercially reasonable control (including any third-party hardware, software or system bugs, defects or malfunctions). No costs or expenses shall be incurred by DocuSign without the prior written consent of DocuSign. In no event shall DocuSign’s total aggregate liability to Customer under or as a result of compliance with the provisions of this Section 7 (“Infringement of Third Party Proprietary Rights”) exceed the total amount payable by Customer to DocuSign under the Order Form or Statement of Work to which the liability relates. The foregoing states Customer’s sole and exclusive remedy, and the entire liability of DocuSign with respect to alleged infringement of any third party proprietary rights by Appliance Subscription Service(s), Equipment or any part thereof or by its operation.
(i) IN NO EVENT WILL DOCUSIGN BE LIABLE TO CUSTOMER FOR (a) REPROCUREMENT COSTS; (b) SPECIAL, INDIRECT OR CONSEQUENTIAL DAMAGES; (c) ANY DAMAGES WHATSOEVER RESULTING FROM LOSS OF USE, DATA OR PROFITS ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT, OR THE USE OR PERFORMANCE OF APPLIANCE SUBSCRIPTION SERVICE, REGARDLESS OF WHETHER THE CAUSE OF ACTION IS IN CONTRACT, TORT, INCLUDING NEGLIGENCE, OR ANY OTHER FORM.
(ii) IN NO EVENT WILL DOCUSIGN’S TOTAL AGGREGATE LIABILTY OF ANY KIND ARISING OUT OF OR RELATING TO THIS AGREEMENT, REGARDLESS OF FORUM AND BASIS OF ACTION OR CLAIM (CONTRACT, TORT, OR OTHERWISE), WILL EXCEED THE TOTAL AMOUNT PAYABLE BY CUSTOMER TO DOCUSIGN UNDER THE ORDER FORM OR STATEMENT OF WORK TO WHICH THE LIABLITY RELATES.
(iii) No person, including any dealer, agent or representative of DocuSign is authorized to assume for DocuSign any other liability on its behalf except as set forth herein. NONPAYMENT OF ANY INVOICE RENDERED WITHIN THE STATED PAYMENT TERMS AUTOMATICALLY CANCELS ANY WARRANTY OR GUARANTEE STATED OR IMPLIED. If DocuSign is due any payment for services performed hereunder, it shall be subject to the same payment terms as the original purchase.
8.2 DISCLAIMER OF WARRANTIES. ALL DOCUSIGN EQUIPMENT, SOFTWARE, PROFESSIONAL SERVICES AND APPLIANCE SUBSCRIPTION SERVICES ARE PROVIDED “AS-IS”. DOCUSIGN DISCLAIMS ALL IMPLIED WARRANTIES FOR EQUIPMENT, SOFTWARE, PROFESSIONAL SERVICES AND APPLIANCE SUBSCRIPTION SERVICES INCLUDING WITHOUT LIMITATION ALL IMPLIED WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE AND NON-INFRINGEMENT. Customer has no right to make or pass on any representation or warranty on behalf of DocuSign to any third party.
9.1 ”Confidential Information” means any trade secrets or other information of DocuSign or Customer, whether of a technical, business, or other nature (such as DocuSign's software), that is disclosed to the other party (the “Recipient”) and that is marked “confidential,” or, whether or not marked, that a reasonable person would understand to be confidential given the circumstances of the disclosure. Confidential Information does not include any information that: (a) was known to Recipient before receiving it from the disclosing party; (b) is independently developed by Recipient without use of or reference to any Confidential Information of the disclosing party; (c) is acquired by Recipient from another source that did not receive it in confidence from the disclosing party to this Agreement; or (d) is or becomes part of the public domain through no fault or action of Recipient.
9.2 Restricted Use and Nondisclosure. During and after the Term, Recipient will: (a) use the Confidential Information of the disclosing party solely for the purpose for which it is provided; (b) not disclose such Confidential Information to a third party, except on a need-to-know basis to its attorneys, auditors and consultants who are under confidentiality obligations at least as restrictive as contained herein; and (c) protect such Confidential Information from unauthorized use and disclosure to the same extent (but using no less than a reasonable degree of care) that it protects its own Confidential Information of a similar nature.
10.2 Notice to U.S. Government End Users. The Software and Documentation are “Commercial Items, “ as that term is defined at 48 C.F.R. §2.101, consisting of “Commercial Computer Software” and “Commercial Computer Software Documentation,” as such terms are used in 48 C.F.R. §12.212 or 48 C.F.R. §227.7202, as applicable. Consistent with 48 C.F.R. §12.212 or 48 C.F.R. §§227.7202-1 through 227.7202-4, as applicable, the Commercial Computer Software and Commercial Computer Software Documentation are being licensed to U.S. Government end users (a) only as Commercial Items and (b) with only those rights as are granted to all other end users pursuant to the terms and conditions herein. Unpublished-rights reserved under the copyright laws of the United States. Copyright 2015 DocuSign, Inc., 221 Main Street, Suite 1000, San Francisco, CA 94105, USA.
10.3 Feedback. Any feedback provided by Customer to DocuSign concerning the functionality or performance of the Software (including identifying potential errors and improvements) (“Feedback”), is hereby assigned by Customer to DocuSign which includes all right, title, and interest in and to the Feedback, and DocuSign is free to make unrestricted use of the Feedback without any necessity of payment to Customer. Customer represents and warrants that at the time of disclosure to DocuSign, Customer is the sole owner of the Feedback or otherwise have the unfettered right or license to make the foregoing assignment.
10.4. Export Rules. Customer may not export or re-export the Software without: (a) the prior written consent of DocuSign; and (b) complying with all applicable export and import control laws and obtaining any necessary permits and licenses.
10.5 Relationship. At all times, the parties are independent actors, and are not the agents or representatives of the other. This Agreement is not intended to create a joint venture, partnership, or franchise relationship, or give rise to any third party beneficiary.
10.6 Assignability. Customer may not assign its rights or obligations under this Agreement without DocuSign’s prior written consent. If consent is given, this Agreement will bind Customer’s successors and assigns. Other than the foregoing, any attempt by Customer to transfer its rights or obligations under this Agreement will be void.
10.7 Force Majeure. Except for any payment obligations, neither party will be liable for failure to perform any obligation under this Agreement to the extent such failure is a force majeure event (including acts of God, natural disasters, war, civil disturbance, action by governmental entity, strike and other causes beyond the party’s reasonable control). The party affected by the force majeure event will provide notice to the other party within a commercially reasonable time and will use commercially reasonable efforts to resume performance as soon as practicable. Obligations not performed due to a force majeure event will be performed as soon as reasonably possible when the force majeure event concludes.
10.8 Mandatory Arbitration. Except for claims: (a) for breach of the confidentiality provisions; (b) arising out of the indemnity obligations; and (c) for injunctive relief, any dispute, claim or controversy arising out of or related to this Agreement or the performance, enforcement, breach, termination, validity or interpretation thereof, including the determination of the scope or applicability of this agreement to arbitrate, that cannot be resolved through good faith discussions between the parties within a reasonable period of time (not to exceed 30 days), will be settled by binding arbitration conducted before one arbitrator. The arbitration shall be administered by the Judicial Arbitration and Mediation Services (“JAMS”) pursuant to JAMS’ Streamlined Arbitration Rules and Procedures, if applicable, or otherwise pursuant to its Comprehensive Arbitration Rules and Procedures and in accordance with the Expedited Procedures in those Rules (the “JAMS Rules”). Either party may submit the matter to arbitration. Such disputes will be resolved by the arbitrator as determined under the JAMS Rules. The arbitration will be conducted in San Francisco County, California, and judgment on the arbitration award may be entered into any court having jurisdiction thereof. Each party will bear its own expenses in the arbitration and will share equally the costs of the arbitration; provided, however, that the arbitrator may, in its discretion, award costs and fees to the prevailing party. Judgment upon the award may be entered in any court having jurisdiction over the award or over the applicable party or its assets. This clause shall not preclude parties from seeking provisional remedies in aid of arbitration from a court of appropriate jurisdiction.
10.9 Governing Law. This Agreement will be interpreted, construed, and enforced in all respects in accordance with the local laws of the State of California, U.S.A., without reference to its choice of law rules to the contrary. Notwithstanding the parties’ agreement to mandatory arbitration, either party may seek any interim or preliminary injunctive relief from a court of competent jurisdiction in San Francisco, CA, as necessary to protect the party's rights or property pending the completion of arbitration. The parties submit to the exclusive jurisdiction of, and venue in, any federal or state court of competent jurisdiction located in San Francisco, California, U.S.A. Any legal action arising under this Agreement must be initiated within two years after the cause of action arises. Each party hereby irrevocably waives, to the fullest extent permitted by law, any and all right to trial by jury in any legal proceeding arising out of or relating to this Agreement.
10.11 Severability. If any part of this Agreement is found to be illegal, unenforceable, or invalid, the remaining portions of this Agreement will remain in full force and effect. If any material limitation or restriction on the grant of any license to Customer under this Agreement is found to be illegal, unenforceable, or invalid, the license will immediately terminate.
10.12 Entire Agreement. This Agreement is the final and complete expression of the agreement between these parties regarding the Appliance Subscription Service(s). This Agreement supersedes, and the terms of this Agreement govern, all previous oral and written communications regarding these matters. These terms and conditions are an essential consideration for DocuSign’s agreement to sell its products and services and shall apply to all DocuSign’s shipments notwithstanding any different, conflicting or additional terms and conditions which may appear on any order submitted by Customer which shall be of no effect other than to specify the Equipment, quantities, price, and requested delivery dates. This Agreement may be changed only by a written agreement signed by an authorized agent of both parties.
This Appliance Subscription Services Developer License (“Developer License”) is a legal agreement between Customer as a “Licensee” and DocuSign, Inc. regarding the use of the Developer Bundle created by DocuSign Inc. and its affiliates (collectively “DocuSign”) for implementing access to DocuSign’s digital signature solution known as Appliance Subscription Services and is incorporated into and made a part of the DocuSign, Inc. Terms and Conditions for Appliance Subscription Services (“Agreement”). This Developer Bundle may include: (i) the SAPI® toolkit, (ii) Appliance Agent software, (iii) Appliance Subscription Service Code Samples, (iv) Appliance Subscription Service Documentation, (v) any and all other software products made available to Licensee under this Developer License (collectively the “Developer Bundle”), and (v) access to the Appliance Subscription Service hosted sandbox for testing the Developer’s implementation. Defined terms not otherwise defined in this Agreement with have the meaning set forth in this Developer License.
1. Grant of License: This is not a sale of the Developer Bundle. Subject to the terms and conditions set forth in this license, DocuSign grants Licensee, a non-exclusive, non-sublicensable, limited, revocable, non-transferable license to use the Developer Bundle for internal use at Licensee’s facilities within the territorial boundaries of the country where this Developer Bundle was delivered to Licensee for non-production purposes, only for the limited purposes of (i) creating interoperability between Licensee products and the Appliance Subscription Service (“Interoperable Product”); (ii) support for the Interoperable Product, and for no other purpose; and (iii) copy and distribute to end users components created by or from the Developer Bundle necessary for interoperability with the Appliance Subscription Service, strictly as an embedded feature of Licensee’s products and not as an independent program. Distribution of any portion of this Developer Bundle to third parties on a standalone basis is strictly prohibited.
4. Ownership: The Developer Bundle is the intellectual property of, and owned by DocuSign and its licensors. Without limiting the generality of the foregoing, the structure, organization and code of the Developer Bundle are trade secrets and Confidential Information of DocuSign and its licensors. The Developer Bundle is protected by law, including without limitation the copyright laws of the United States and other countries, and by international treaty provisions. Except as expressly stated herein, this License does not grant Licensee any intellectual property rights in the Developer Bundle, and all rights not expressly granted are reserved by DocuSign and its suppliers. Licensee agrees that upon request from DocuSign or DocuSign’s authorized representative, Licensee will within 30 days fully document and certify that use of any and all Developer Bundle at the time of the request is in conformity with Licensee’s valid licenses from DocuSign.
5. Restrictions: Licensee will not copy the Developer Bundle, except to make a back-up copy that is not installed or used on any computer. Any copy of the Developer Bundle that Licensee makes must contain the same copyright and other proprietary notices that appear on or in the Developer Bundle. Licensee shall not: (i) adapt, alter, modify, translate, create derivative works of, reverse compile, disassemble, merge or otherwise attempt to reconstruct the source code of the Developer Bundle; (ii) use the Developer Bundle for any purpose that is not authorized in the documentation; (iii) allow use of the Developer Bundle in any manner that allows internal access to its functionality other than through the user interface of the Licensee’s products that incorporate the Developer Bundle; (iv) create interoperability between the Developer Bundle and any third party’s products that provide functionality similar to the Appliance Subscription Service; (v) assign, pledge, rent, lease, loan or timeshare the Developer Bundle; (vi) alter the standard “look and feel” of the Appliance Subscription Service user interface, as implemented by the Developer Bundle and depicted in its user manuals; (vii) obfuscate, remove or alter any of the trademarks, trade names, logos, patent or copyright notices, confidential or proprietary rights notices or legends or other notices or markings on or in the Developer Bundle without DocuSign’s express written consent; (viii) publish or otherwise disclose to any third party the results of any analysis, benchmark or other tests on the Developer Bundle; (ix) copy any portion of the Developer Bundle for any purpose not expressly allowed under this Developer License; (x) distribute the Developer Bundle except in the manner expressly allowed under this Developer License; or (xi) impose any fee or added cost on Licensee’s customers or end users for use of any of the Appliance Subscription Service functionality.
7. Warranty. Except as otherwise expressly set forth herein, DOCUSIGN PROVIDES THE DEVELOPER BUNDLE AND ANY SERVICES PROVIDED UNDER THIS DEVELOPER LICENSE “AS IS,” WITHOUT WARRANTY OR CONDITION OF ANY KIND, WHETHER EXPRESS, STATUTORY, IMPLIED OR OTHERWISE, INCLUDING WITHOUT LIMITATION, ANY WARRANTY OR CONDITION OF MERCHANTABILITY, SATISFACTORY QUALITY, FITNESS FOR A PARTICULAR PURPOSE, ERROR-FREE OR CONTINUOUS OPERATION AND NON-INFRINGEMENT. LICENSEE WILL UNDERTAKE ANY AND ALL DEVELOPMENT AT LICENSEE’S OWN RISK, INCLUDING ALL RESPONSIBILITY FOR LICENSEE PRODUCT(S).
9. Termination: This Developer License will be effective upon the Effective Date, and shall automatically terminate on the earlier of: (i) the expiration or termination of Licensee’s right to receive the Appliance Subscription Service(s); or (ii) DocuSign’s termination of this Developer License, as permitted herein. Notwithstanding anything to the contrary herein, DocuSign may (at its sole discretion) suspend or terminate this Developer License if Licensee fails to comply with any term of this Developer License.
9.1 Effect of Termination. Upon termination of this Developer License, Licensee shall cease all use of the Developer Bundle and if requested by DocuSign, certify in writing to DocuSign that all copies of the Developer Bundle have been destroyed or deleted from any and all computer libraries or storage devices in Licensee’s possession and/or control. In addition to the terms that survive in the main body of the Agreement, the following Developer License sections will survive: Sections 4, 6 through 13, and all definitions of defined terms.
12. Notice to U.S. Government End Users. The Developer Bundle and Documentation are “Commercial Items,” as that term is defined at 48 C.F.R. §2.101, consisting of “Commercial Computer Software” and “Commercial Computer Software Documentation,” as such terms are used in 48 C.F.R. §12.212 or 48 C.F.R. §227.7202, as applicable. Consistent with 48 C.F.R. §12.212 or 48 C.F.R. §§227.7202-1 through 227.7202-4, as applicable, the Commercial Computer Software and Commercial Computer Software Documentation are being licensed to U.S. Government end users (a) only as Commercial Items and (b) with only those rights as are granted to all other end users pursuant to the terms and conditions herein. Unpublished-rights reserved under the copyright laws of the United States. Copyright 2015 DocuSign, Inc., 221 Main Street, Suite 1000, San Francisco, CA 94105, USA.
13. Conflict. If there is a conflict between the main body of the Agreement and this Developer License, the terms and conditions of this Developer License will govern and control as to this Developer License subject matter.

References: §2
 §12
 §227
 §12
 §2
 §12
 §227
 §12