Source: https://www.lienitnow.com/south-dakota-property-lien-statutes
Timestamp: 2019-04-22 17:59:53+00:00

Document:
The provisions of the South Dakota statutes that permit the filing of mechanics liens and materialman's liens on construction projects can be found in South Dakota's Mechanics' Lien Law, SDCL § 44-9-1 et. seq. The full text of the South Dakota Construction Lien Law is provided below, and has been updated as of 2011. To see a quick synopsis of the most important provisions, take a look at our South Dakota Frequently Asked Questions page.
(3) Upon any mine or mining claim, oil or gas well or spring, a lien upon the same and any rights, privileges, franchises, easements, and tangible property and other property or appliances appurtenant thereto, for any of the items hereinbefore specified or referred to as giving right to a lien.
When improvements are made by one person upon the land of another, all persons interested therein otherwise than as bona fide prior encumbrancers or lienors shall be deemed to have authorized such improvements, insofar as to subject their interests to the liens therefor; provided that as against a lessor no lien is given for repairs made by or at the instance of his lessee.
Whenever land is sold under an executory contract authorizing the vendee to improve the same, and such contract is forfeited or surrendered after liens have attached by reason of such improvements, the title of the vendor shall be subject thereto, but he shall not be personally liable if the contract was made in good faith.
Click Here to File a South Dakota Document.
Any person who has not authorized the improvement may protect his interests from such liens by serving upon the persons doing the work or otherwise contributing to such improvement, within five days after knowledge thereof, written notice that the improvement is not being made at his instance, or by posting like notice, and keeping the same posted, in a conspicuous place on the premises.
The lien shall not extend to nor affect any rights in any homestead so far as the same is exempt from levy and sale on execution.
If the contribution be made under a contract with the owner and for an agreed price, the lien as against him shall be for the sum so agreed upon together with the cost of any additional material or work agreed upon, otherwise, and in all cases as against others than the owner, it shall be for the reasonable value of the work done, and of the skill, material, and machinery furnished.
The interest payable on amounts secured by mechanics’ or materialmen’s liens shall be at the maximum interest rate allowed in § 54-3-5.1.
Such lien as against the owner of the property shall attach and take effect from the time the first item of material or labor is furnished upon the premises by the lien claimant, and shall be preferred to any mortgage or other encumbrance not then of record, unless the lien holder had actual notice thereof.
As against a bona fide purchaser, mortgagee, or encumbrancer without notice, however, no lien shall attach prior to the actual and visible beginning of the improvement on the ground, but a person having a contract for the furnishing of labor, skill, material, or machinery for such improvement, may file with the register of deeds of the county within which the premises are situated or of the county to which such county is attached for judicial purposes, or if claimed under subdivision 44-9-1(2), with the secretary of state, a brief statement of the nature of such contract, which statement shall be notice of his lien for the contract price or value of all contributions to such improvement thereafter made by him or at his instance.
All liens, claims for labor performed, or services or materials furnished, as provided in subdivision 44-9-1(3), shall be concurrent liens upon the property charged and shall be paid pro rata out of the proceeds arising from the sale thereof, if the same shall be sold, or upon settlement without sale.
Any person furnishing any of the items for which a lien may be claimed under the provisions of § 44-9-1 under a contract, either express or implied between the owner of the property or his duly authorized agent or representative, and any contractor working upon or about such property may serve upon the owner, or his duly authorized agent or representative at any time, a sworn account and notice of his claim showing the items and amounts and the dates that the same were furnished, and thereupon the owner shall withhold from his contractor so much of the contract price as may be necessary to meet the claims of persons who have served such accounts and notices.
Whenever any such account and notice is served upon the owner of the property or his duly authorized agent or representative, he shall furnish his contractor with a copy of the same, and if such contractor shall not within fifteen days after the receipt of such account and notice give the owner, his agent, or representative, written notice that he intends to dispute the claim, he shall be considered as assenting thereto and such owner may pay the same to the claimant when it becomes due and deduct the amount out of any moneys due such contractor, who may in like manner deduct such amount from any moneys due from him to his subcontractor or the claimant.
The amount which may be due from any contractor to his creditor may be recovered from said owner by the creditor of said contractor, in any action at law, to the extent and value of any balance due by the owner to his contractor under the contract with him, at the time of the notice first given as provided in § 44-9-10, or subsequently, according to such contract or under the same.
Any contractor, subcontractor, or supplier on any improvement of real estate, mines, or public utilities within the purview of this chapter who knowingly uses more than five hundred dollars of the proceeds of any payment made to him on account of such improvement by the owner of such real estate or person having the improvement made, for any other purpose than the payment for labor, skill, materials, and machinery contributed to such improvement while any account for such labor, skill, material, or machinery furnished for such improvement up to the time of such payment remains unpaid and due and owing under the credit terms arranged, is guilty of theft of the proceeds of such payment. It is not a violation of this section to withhold funds from a contractor, subcontractor, or supplier pending the completion and final approval of his work or product.
The owner, by serving written request within fifteen days after the completion of the contract, may require any person who may have a lien under the provisions of this chapter, to furnish him an itemized and verified account of his lien claim, the amount thereof, and his name and address. No action or other proceeding shall be commenced for the enforcement of such lien until ten days after such statement is so furnished pursuant to the request of the owner.
The word “owner” as used in this section shall include any person interested in the premises otherwise than as a lien holder thereunder.
The lien shall cease at the end of one hundred twenty days after doing the last of such work, or furnishing the last item of such skill, services, material, or machinery, unless within such period a statement of the claim therefor be filed with the register of deeds of the county in which the improved premises are situated, or of the county to which such county is attached for judicial purposes, or if the claim be under the provisions of subdivision 44-9-1(2), with the secretary of state.
(7) An itemized statement of the account upon which the lien is claimed.
Before filing such lien statement, the person claiming the lien shall mail to the property owner at his last known post office address, by registered or certified mail, a copy of such lien statement and the post office receipt for such mailing shall be attached to the lien statement and filed in the office of register of deeds.
The register of deeds shall file such statement or lien in numerical order and enter the same upon a register to be kept for that purpose containing the name of the owner of the property against whom the lien is claimed, date of filing, amount, description of the property affected by the lien, and a blank space for the date of release. In addition, if such lien affects the title to real property, he shall enter the same upon the mortgage or lien index described in § 7-9-9.
The register of deeds shall charge a fee in accordance with subdivision 7-9-15(3) for the filing and indexing of any lien or assignment of the lien under the provisions of this chapter. However, no fee may be charged for the satisfaction of the lien.
Except as in the case of condominiums under the provisions of § 43-15A-29, a lien holder who contributes to the erection, alteration, removal, or repair of two or more buildings or other improvements situated upon or removed to one lot, or upon or to adjoining lots, under or pursuant to the purposes of one general contract with the owner, may file one statement for his entire claim, embracing the whole area so improved. Alternatively, he may apportion his demand between or among the several improvements and shall assert a lien for a proportionate part upon each and upon the ground appurtenant to each respectively.
Whenever a lien has been claimed by filing the same in the office of the register of deeds and it is afterward satisfied by payment, foreclosure, compromise, or other method, the creditor shall execute and deliver to the owner of the property a satisfaction describing the lien by its date, date of filing, amount claimed, description of the property, and the names of the lien claimants and owner of the property. Such satisfaction shall be executed before two witnesses or acknowledged before a notary public, and upon presentation to the register of deeds, he shall file the same and cancel the said lien of record.
If any holder of a lien under the provisions of this chapter shall neglect to execute and deliver such satisfaction within ten days after written demand therefor by the owner of the property or any person interested therein, when such lien has in fact been satisfied as provided in § 44-9-21, he shall be liable to the person demanding such satisfaction for all damages, costs, and expenses, including attorney’s fees, and an additional penalty of one hundred dollars.
The lien may be enforced by action in the circuit court of the county in which the improved premises or some part thereof are situated, or of the county to which such county is attached for judicial purposes, or, if claimed under subdivision 44-9-1(2), of any county through or into which said railway or other line extends, which action shall be begun and conducted in the same manner as actions for the foreclosure of mortgages upon real estate, except as herein otherwise provided.
No lien shall be enforced in any case unless the holder thereof shall assert the same, either by complaint or answer, within six years after the date of the last item of his claim as set forth in the filed and entered lien statement; nor shall any person be bound by the judgment in such action unless he is made a party thereto within said six years.
The action to foreclose the lien may be commenced by any lien holder who has filed his lien statement as required in this chapter, and all other such lien holders who are not joined with him as plaintiffs shall be made defendants. Any such lien holder not named as a defendant may nevertheless answer the complaint and be admitted as a party. All parties having liens under this chapter may join as plaintiffs, if they so desire, prior to the commencement of any action by a single lien holder.
(3) Proof of service on the person holding the lien.
The action shall be commenced by issue of a summons and filing complaint in the office of the clerk of courts.
At the beginning of the action the plaintiff shall file for record with the register of deeds of the county in which the action is pending and of the several counties into which the utility extends, if the lien is claimed under subdivision § 44-9-1(2), a notice of the pendency thereof. After such filing no other action shall be commenced for the enforcement of any lien arising from the improvement described, but all such lien claimants shall intervene in the original action by answer as provided in § 44-9-25.
Upon the application of the plaintiff, or anyone claiming an interest in the property, the court may make an order requiring all persons claiming any interest in the property or lien thereon to appear in the action, either by complaint in intervention or by answer, and to set up whatever rights, claims, or interests they may have in and to the property involved in the action, within a time to be fixed by the court in its order, which shall not be less than sixty days after the first publication of the same. The order shall be published in a legal newspaper of the county once each week for at least four weeks, and if within the time specified in said order, any party shall not appear and assert his claim by proper pleading, he shall be forever barred from claiming any right, lien, or interest against the property, and judgment shall be entered in favor only of those who appear and establish their liens, claims or interests.
If more than one action shall be commenced in good faith for foreclosure of liens upon the same property, all shall be consolidated and tried as one, under such order of the court as may best protect the rights of all parties concerned.
Each lien holder shall attach to and file with his complaint or answer a bill of the items of his claim, verified by the oath of some person having knowledge thereof, and shall file such further and more particular account, as the court may at any time direct. Upon his failure to file such original or further bill, his pleading shall be stricken out and his claim disallowed.
All averments of the answer shall be deemed denied without further pleading.
All provisions of Title 15 shall be applicable to foreclosure actions under this chapter, except where a different intention plainly appears from the provisions of this chapter.
Whenever action has been commenced for the foreclosure of liens, under this chapter, and a majority of the lien holders, parties to such action, shall by motion request the appointment of a receiver, the court may appoint a receiver to take possession of all the property covered by such liens and to take care of and preserve the same.
In all cases of liens arising under the provisions of subdivision § 44-9-1(2) a receivership may be created in the first instance instead of directing a sale of the property.
The court may authorize such receiver to issue receiver’s certificates to persons furnishing services, supplies, or equipment only to the extent necessary for preservation of such property, and for taxes, insurance, and similar charges necessary to protection of the property. Such certificates may be made prior and preferred claims to all other liens of every kind and character, except court costs and expenses of sale, if such priority and preference shall be deemed necessary by the court for proper preservation and care of the property. The provision for such receiver’s certificates may be made in the judgment of foreclosure or in any intermediate judgment or supplemental judgment.
The compensation of the receiver shall be fixed at a reasonable daily rate by order of the court for each day that the receiver is actually engaged in the performance of his duties.
Nothing in §§ 44-9-34 to 44-9-37, inclusive, shall abridge the power of the court otherwise to appoint a receiver under the provisions of chapter 21-21.
If upon the trial of such action, or at any time before the rendition of final judgment therein, it shall appear to the satisfaction of the court that a proper party who may still be brought in has been omitted, or that any party then entitled to answer has not yet appeared, or that for any other reason the trial or judgment should be delayed, or the judgment as ordered or entered be modified, the court may postpone the trial, or make such other or further order in the premises as shall be just, and if it be found that any indebtedness for which a lien is demanded be not then due, the same shall be allowed for the amount of its present worth.
Judgment shall be given in favor of each lien holder for the amount demanded and proved by him, with costs and disbursements to be fixed by the court at the trial, and such amount shall not be included in the lien of any other party.
The clerk of the courts shall tax the same costs as are allowed in foreclosures of real estate mortgages.
The lien claimant shall be entitled to tax as costs, in addition to all other costs allowed by law, the sum of five dollars for the preparation of the lien statement and account for filing with the register of deeds.
The court shall have authority in its discretion to allow such attorney’s fees and receiver’s fees and other expenses as to it may seem warranted and necessary according to the circumstances of each case, and except as otherwise specifically provided in this chapter.
If, after judgment, a lien holder who is personally indebted for the amount of any lien so adjudged in favor of another shall pay such indebtedness, he shall thereby become subrogated to the rights of the person so paid.
The judgment shall direct a sale of the real estate or other property for the satisfaction of all liens charged thereon, and the manner of such sale, subject to the rights of all persons which are paramount to such liens or any of them. It shall require the officer making such sale to pay over and distribute the proceeds of the sale, after deducting all lawful charges and expenses, to and among the lienors to the amount of their respective claims, if there is sufficient therefor; and if there is not sufficient then to divide and distribute the same among the several lienors in proportion to the amount due to each, and without priority among themselves.
If the estate sold be a leasehold having not more than two years to run, or be the interest of a vendee under an executory contract of sale the conditions whereof are to be performed within the same period, no redemption shall be allowed; in all other cases the right of redemption shall be the same as upon execution sales.
If, without material injury to the building or other improvement to which the lien holder has contributed, the same can be severed and removed from the land, the judgment, in the discretion of the court, may direct the sale of such improvement, with the privilege to the purchaser of removing the same at any time within sixty days, unless before such removal the owner or other persons interested in the land shall pay to the sheriff, for the purchaser, the amount realized from the sale, with interest and all expenses incurred toward such removal.
No sale shall be deemed complete until reported to and confirmed by the court.
If in any case the sale be not confirmed, the court may direct a resale, or if deemed best may appoint a receiver to lease or otherwise handle the property under its direction, in the interests of all persons concerned.
No failure to comply with any of the provisions of this chapter shall affect the right of any person to recover, in an ordinary civil action, from the party with whom he has contracted.
(4) The location of the project, including the legal description of the property.
The notice shall be filed within thirty days of the commencement of work and shall be accompanied by a filing fee of ten dollars to be deposited in the county’s general fund. The register of deeds in each county shall maintain an index of all notices of project commencements.
Any person filing a notice of project commencement shall post the name and address of the contractor and location notice at the job site. The location notice shall contain the following statement: The contractor on this project has filed a notice of project commencement at the county courthouse. Any sub-subcontractor and any supplier to a subcontractor shall comply with the notice provisions of § 44-9-53 before filing liens in connection with this project.
The filing of a notice of project commencement does not constitute a cloud, lien, or encumbrance upon, or defect to, the title of the real property described in the notice, nor does it alter the aggregate amounts of liens allowable by applicable statute, nor does it affect the priority of any mortgage or future advances under any mortgage.
Any person who gives notice in accordance with this section may extend a lien as provided in § 44-9-15.
This section does not apply to claims of individual laborers when the amount of their lien is less than two thousand dollars.

References: § 44
 § 54
 § 44
 § 44
 § 7
 § 43
 § 44
 § 44
 § 44
 § 44
 § 44
 § 44