Case: THE PACIFIC HARDWARE AND STEEL COMPANY v. THE UNITED STATES
Abbreviation: Pacific Hardware & Steel Co. v. United States
Decision Date: 1913-05-19
Docket Number: No. 31187
Citation: 48 Ct. Cl. 399
Volume: 48
Reporter: United States Court of Claims Reports
Court: United States Court of Claims
Jurisdiction: United States
Parties: THE PACIFIC HARDWARE AND STEEL COMPANY v. THE UNITED STATES.
Judges: Howrv, J., not having heard the argument in this case, reserves his decision thereon.
Pages: 399–408

Head Matter:
THE PACIFIC HARDWARE AND STEEL COMPANY v. THE UNITED STATES.
[No. 31187.
Decided May 19, 1913.]
On the defendants’ Demurrer.
The contract is for the delivery of supplies to the Isthmian Canal Commission with a provision that in case of delay beyond the contract time there shall be a prescribed deduction from the contract price for every day of such delay; but if the delay has been caused by the acts of other parties in transit or delivery, or if no damage or inconvenience has been suffered by the Government, the chairman of the commission will waive said such deductions.
I. Courts prefer to consider stipulations for damages in contracts as penalties rather than as liquidated damages. When treated as a penalty, the recovery can be apportioned to actual damages. Cases should be decided upon a just consideration of all the terms and purposes of the contract, of the relation of the parties to it, of the objects of the same, and of the duty to be performed.
II. The use of either of these terms in a contract is not conclusive; “liquidated damages” may appear from the context to be really a penalty; and a “ penalty ” may be shown by the intention of the parties to be liquidated damages.
III. A provision in a contract that the proper officer may waive the damages, and that where none have resulted from the delay none will be exacted, indicates that penalty was really intended by the parties. The difference between this and the Bethlehem Steel Oo.’s Oase (205 IJ. S. B., 105) defined.
IV. Where there is ambiguity in the contract it will be construed more strictly against the party who prepared it.
The Reporter’s statement of the case:
The allegations of the petition demurred to will be found stated in the opinion of the court.
Mr. Benjamin F. Harrah and Mr. S. 8. Ashbaugh (with whom was Mr. Acting Assistant Attorney General F. De G. Faust) for the demurrer:
I believe that the Government has the right to provide by contract for such contingencies as its experience shows are liable to arise in the transaction of its great and diversified business, and that contingencies and conditions governing them may properly be made the subject of competition in the letting of contracts, and that, if made the subject of competition in the letting of a contract and they become subsequently an integral part of such contract, the rights growing out of such contingencies should be honestly and fairly enforced. The words used to express such rights growing out of the happening of the contingencies, when considered in connection with the whole instrument and the objects and purposes sought to be accomplished by the contract, shoúld be given their ordinary and usual meaning, unless they conflict with words used in other clauses of the contract. The rule that I think should govern in the construction of the words used in this contract is stated in the case of Sturges v. Orowninshield (4 Wheat, 120, 200).
To the same effect is the case of the United States v. Bethlehem Steel Co. (205 U. S., 105, 119) and the case of the United Shoe Machinery Co. v. Abbott (158 Fed. Rep., 762).
I do not believe that there is a single contingency named in the proviso that may not be made the subject matter of a contract provision. The measure of damages is fixed in the obligation part of the contract. The conditions under which it shall not apply are stated in the proviso.
To construe the contract as a whole as a penalty is but to destroy it.
That the parties intended in this case that the deductions should be made from the contract price as a measure of the damages suffered in all cases not within the exceptions noted in the proviso does not seem to me to admit of a reasonable doubt. To give the language any other construction renders it senseless and meaningless and makes the whole provision nothing but a jumble of words. But it is insisted that the incorporation of the condition that “ if the Government has suffered no damage or inconvenience on account of the delay ” is evidence within itself that the provision for a deduction could not have been intended as a measure of damages. These two provisions are not inconsistent with each other. The contract was made from the standpoint of the situation as it was seen at the time it was entered into. It was also contemplated as is shown by these provisions that the situation and circumstances might so change prior to the time the delivery was required as to render it certain that there would be no damage or inconvenience. (A. Lesehen, & Sons Rope Go. v. May-flower Gold Mining Go., 173 Fed. Bep., 855.)
Inconvenience that would result from one of two constructions of a statute is recognized as something that may be taken into consideration in determining the true meaning of the statute (U. S. v. Fisher, 2-Cranch, 358, 385.)
The consequences that might flow from the inconvenience that would be suffered by the Government on account of the delay is, in my opinion, a proper subject to be covered by a provision in a contract, and where it can be shown as a fact that no inconvenience was suffered, such fact will support an express promise to waive the measure of damages agreed upon. It not infrequently happens in the prosecution of work, or the delivery of material, that the Government would be damaged or inconvenienced by the delivery of the material called for on the date specified in the contract, and in such case the inconvenience that would be suffered by the Government, if delivery was made on such date, is sufficient consideration for postponing the delivery, even in a contract providing for liquidated damages.
It can not be said as a matter of law that there can be no inconvenience without damages, although it might be said as a matter of law that there can be no damage without inconvenience. I do not think that the terms are necessarily convertible, but I do think that the Government has as much right to stipulate in its contracts the consequences that shall flow from the fact when developed that no inconvenience has been suffered, as it has to stipulate a fixed sum as damages in certain cases where the amount of damages are of an uncertain nature and difficult of ascertainment. The stipulation reduced to its last analysis is simply one to meet a condition that may arise and one the consequences of which it is deemed wise to place within the discretion of. the officer charged with the execution of the contract. Such stipulations, when reasonable, are always upheld as within the rights of parties competent to contract, to make.
A settlement with this contractor enforcing the deductions authorized, especially if he protested, would amount to an exercise of the discretion conferred upon the bureau officer under the well-recognized rule that, whatever is necessary to be decided as a condition precedent to the right to act must be presumed to have been decided in the absence of a showing to the contrary. Furthermore, if it be admitted that the true construction is doubtful, which we do not, if the settlement was acquiesced in and payment accepted without protest, it would amount to a practical construction of the contract binding upon the parties. (TopUff v. TopUff, 122 ü. S., 121, 131.)
Reduced to its last analysis, the claimant is asking the court to decide that the elaborate provision in this contract for a deduction of a reasonable and graduated percentage from the contract price for the default, except in the event of the happening of certain specified things, does not mean anything more than the contract would mean with the proviso standing alone as an independent provision, with all reference to any deduction from the price eliminated. If it never was intended that the deductions should be made as a measure of the damages for the specified default, why go into such details in saying they should be made, and why specify in such detail the condition under which they should, in the discretion of the bureau, be waived? It is senseless to give the express right to waive a provision in a contract which within itself, under the construction contended for by the claimant, would be inoperative for the purpose covered by the waiver, even without the waiver. It is certainly not the province of the court to construe the language in a contract so as to render it inoperative if any other construction can be indulged. This principle is aptly and forcibly stated in the case of the United Shoe Machinery (Jo. v. Abbott (158 Fed. Pep., 762).
Mr. FrederioJe B. Rhodes opposed.

Opinion:
AteiNSON, J.,
delivered the opinion of the court:
In this cause the defendants demur generally "that the petition does not allege facts sufficient to constitute a cause of action."
The plaintiff company in its petition in substance alleges that it entered into various and sundry contracts with the Navy Department, through the Chief of the Bureau of Supplies and Accounts, during the years 1905 and 1906, whereby it agreed to deliver to the Isthmian Canal Commission on the Isthmus of Panama within certain prescribed periods certain materials to be used by said commission. The contracts, which are made a part of plaintiff's petition, provided that in case there was delay in delivery beyond the contract time there should be a deduction from the contract price at the rate of one-tenth of 1 per cent of the total cost of the undelivered material for every day of such delay; and further, that delays on account of which such deductions may be made as therein stated, caused by strikes, riots, fire, or other disaster, or delays in transit, or delivery, on the part of transportation companies, or when no damage or inconvenience had been suffered by the Government, might in the discretion of the chairman- of the ' Isthmian Canal Commission be accepted as sufficient cause for waiving said deductions.
Under dates of February 2,1906, April 2 and August 9 of said year, there was deducted, respectively, the sums of $94.08, $27.46, and $8, making a total of $129.54, on account of the failure of plaintiff to deliver materials within the time provided in the contracts; and to recover said amount this suit was instituted.
The only question to be disposed of by the court is whether the provision in the contracts, to which we have referred, is to be considered as liquidated damages or as a penalty only. Questions of this character are often difficult to determine. It is agreed, however, that the courts always prefer to consider stipulations for damages in contracts as provisions for penalties rather than for liquidated damages; that such provisions will always be construed as penalties in doubtful cases is likewise accepted; and unless the contrary intention is unequivocally expressed harsh provision will be avoided and compensation in the way of penalty will be decreed, for by treating such sum as a penalty the recovery can be apportioned to actual damages for the loss sustained, and the compensation for that loss is a full measure for the injuries imposed. As stated above, upon a just consideration of all the terms and purposes of a contract, of the relation of the parties to it, of the objects and purposes of the same, and of the duty to be performed, whether the sum stated was intended as liquidated damages or as a penalty, if doubtful, it will be construed in such cases as penalty only. (Sedgwick on Damages, vol. 2, 209; 13 Cyc., 90 and 95, and cases there cited; Chicago Wrecking House Co. v. The United States, 106 Fed., 385, 389; 13 L. R. A., 672; Edgar Thompson v. United States, 34 C. Cls. R., 305; Smith Co. v. United States, ib., 472; Holliday v. The United States, 33 C. Cls. R., 453; Wait on Actions and Defenses, vol. 2, 435; Sutherland on Damages, vol. 1, 475 et seq.; 5 Amer. and Eng. Em, 24, and cases there cited.)
Plaintiff's counsel insists that the clause of the contracts in this case should not be considered as providing for liquidated damages, because that would be inconsistent with the other provisions which gives discretion to the Canal Commission to remit them, and for the further reason that if the damages were liquidated they would have immediately vested in the United States. The proposition, he contends, is well established that no Government official has authority to waive or remit damages accrued to the Government under a contract which provides for liquidated damages, and that such, damages are as much an asset of the United States as the funds in its Treasury. Hence, a Government officer, in making a contract for the United States, can not effectively reserve to himself the right of remission of accrued damages without violating a liquidated-damage clause.
He further argues that when these Isthmian Canal contracts were prepared, it was well known that there had been a uniform line of decisions by the Comptroller of the Treasury that if damages were liquidated a vested right had been obtained by the Government (11 Comp. Dec., 395; 17 ibid., 33, 83) ; that none of its officers possessed the right to waive the same, and that it was immaterial whether or not any damage had been sustained by the Government. If, therefore, the clause in the contract means anything, it means that the contractor will not sustain loss where the delay has caused no damage to the Government.
On the other hand, counsel for the United States contends that the contracts herein substantially liquidated the damages, notwithstanding the discretionary wording of the waiving provision inserted for the contractor's benefit, viz, that " where delays are caused by strikes, riots, fires, or other disasters, or delays in transit or delivery on the part of transportation companies, or if the Government has suffered no damage or inconvenience on account of the delay, the deduction provided for may, in the discretion of the bureau, be waived; " but such discretion the chairman of the commission, for reasons of his own, which were not made known, saw fit not to exercise; consequently the plaintiff, by setting up a breach of the contracts on its part and performance by the Canal Commission, should not be permitted to recover the amounts claimed by it in this case. The intention of the parties, he insists, was to liquidate the damages by the contracts, because of the long distance between the canal and the bases of supplies and the inability of the Government itself to purchase the articles elsewhere for which the contracts to supply the same were made, in case they were not forthcoming at the dates specified in the several contracts.
It is further contended by the defendants that damages in cases of this character are of an uncertain nature, hence the practice of the Government requires free, open, and fair competition in the letting of public contracts. In order to secure this it is usual in the advertisement to name the conditions which shall govern in any particular purchase. In order to meet the conditions arising in the Government service and to preserve an orderly sequence in the receipt of the various articles which a department may need in carrying on the business of that department it is necessary to fix in contracts the time when deliveries of particular articles called for under them may be demanded. It is, therefore, difficult to determine the actual probable damages that will result to the Government from delayed deliveries in any particular service.
Defendants cite a long line of authorities in support of the proposition that the intent and meaning of the term liquidated damages is to be damages agreed upon by the parties to a contract for compensation for and in lieu of the actual damages arising from the breach of a contract. They are amounts fixed, settled, and agreed upon in advance to avoid litigation as to damages actually sustained. They may exceed or fall short of the actual damages sustained, but the sum thus fixed and determined binds the parties to such agreement. When this sum is paid, in the absence of any other agreement, all damages arising from such breach are paid.
This doctrine, however, is elementary, and has been affirmed by both State and Federal appellate courts for generations. But courts have frequently decided that the sum stipulated to be paid on the breach of an agreement to be, from the nature of the case, a penalty, notwithstanding the strongest language showing the appai'ent intention of the parties to be that it should be paid in full as liquidated damages. So, too, cases are numerous in which the parties have used the term " penalty," which seems on its face to impart a forfeiture rather than a valuation of damage, yet the stipulated sum, from the very nature of the case, should be considered as liquidated damages and recoverable in full. Page on Contracts (sec. 1172) says, in substance, that the use of either of these terms in a contract is not conclusive; that liquidated damages may appear from the context of the contract to be really a provision for a penalty and will be so treated. On the other hand, a contract for a penalty may be shown, by the intention of the parties to be liquidated damages. The question, therefore, must be determined by surrounding conditions and the intent of the parties to the contract.
If the right to remit liquidated damages can not be reserved in a Government contract without specific authority from the Congress, then, it seems clear to us, it must follow that the clause of the contracts now under consideration must either be construed as a penalty or it must be held that the proviso attempting to reserve to the chairman of the Isthmian Canal Commission the right to remit the deductions is necessarily without effect, and under such an alternative the clause should be construed as a provision for penalty under the rule which requires a contract to be so construed as to give effect to all of its parts.
Considering further the proviso in the contract in the case at bar, that under certain conditions the chairman of the Isthmian Canal Commission may, in his discretion, waive the deduction for damages, indicates, we think, clearly that the question of damages should be examined into, in case it should become a matter of controversy, and if it is shown that no damages have resulted from the delays, it would appear that the parties to the contract did not intend to fix the rate of damages in advance, or rather when the contract was executed. In other words, it was intended that if the delays provided for in the contract caused no actual damage, the damage clause was to be waived. If this view is correct, and we think it is, the proviso covers a penalty and not liquidated damages. Where there is ambiguity in a contract it is a familiar principle of law that it will be construed more strictly against the party that prepared it, which contract in this case was prepared by the defendants. (Thompson 'Works v. United States, 34 C. Cls. R., 205, 219; Garrison v. United States, 7 Wall., 688.)
As a matter of first impression (Crane & Co. v. United States, 46 C. Cls. R., 343), we were of the opinion that the provision relating to damages in the class of contracts we are now considering was controlled by the case of the Bethlehem Steel Co. v. United States (205 U. S., 105), but upou more mature reflection we have arrived at the conclusion that that case is not this one. In that case no provision was made for relieving the contractor from the penalty upon any particular ground, as was done in the case at bar. In that case the Supreme Court, when considering only the language of the contract, found it difficult to determine whether the parties intended to provide for liquidated damages or a penalty; but when it examined into the prior negotiations it found them to be such as to lead the court to the conclusion that the parties to the contract intended the provision to mean liquidated damages, and so decided.
In the case we are now considering a number of exceptions are enumerated under which the penalty clause is not to apply, and in addition thereto it is expressly stated that where the delay does not cause damage or inconvenience to the Government the penalty shall not be charged against the contractor when waived by the Canal Commission. (See U. S. Engineering and Contracting Co. v. United States, 41 C. Cls. R., 489, and the numerous cases there cited.)
It follows from what we have said that the defendant's demurrer must be overruled with leave to both parties to take further testimony, if desired, within ninety days.
It is so ordered.
Howrv, J., not having heard the argument in this case, reserves his decision thereon.