Case: UNITED AND GLOBE RUBBER MANUFACTURING COMPANIES v. THE UNITED STATES
Abbreviation: United & Globe Rubber Manufacturing Companies v. United States
Decision Date: 1916-05-08
Docket Number: No. 31914
Citation: 51 Ct. Cl. 238
Volume: 51
Reporter: United States Court of Claims Reports
Court: United States Court of Claims
Jurisdiction: United States
Parties: UNITED AND GLOBE RUBBER MANUFACTURING COMPANIES v. THE UNITED STATES.
Judges: 
Pages: 238–250

Head Matter:
UNITED AND GLOBE RUBBER MANUFACTURING COMPANIES v. THE UNITED STATES.
[No. 31914.
Decided May 8, 1916.]
On the Proofs.
Contract.—Plaintiff enters into a contract with the Government to furnish certain quantities of suction hose to be delivered on the Canal Zone, and the specifications thereof require a specific friction test for quality. At various times the hose is delivered and inspected by the Government officials and successfully passes all the requirements of the contract, and no complaint is made in respect thereto until after the expiration of from three to eight months, when having been put to actual use on the Isthmus a certain amount of the hose is rejected as being defective. During the course of the contract the agreement in regard to furnishing of lengths for tests is modified, the plaintiff warranting, in view of a waiver of this requirement, that the hose furnished under the contract be the equal in all respects of the sample furnished for test.
Same; plans and specifications.—Where “ suction hose ” is required by a contract and the specifications generally describe the article desired, the contractor is required only to furnish the hose in compliance therewith and not such suction hose as is generally understood among the trade.
Delivery; test; inspection; acceptance.—Where merchandise is to be manufactured and delivered under certain specifications and subjected to prescribed inspections and tests,'meets such requirements, and no complaint is made within a reasonable time after its delivery, it is equivalent to a final acceptance and the transaction under the contract is closed. No belatedly applied test demonstrating an alleged defect can serve to reopen the matter.
Breach of warranty; inspection; test.—The Government having failed to apply the prescribed test to the hose furnished, there was no breach of the express warranty on the part of plaintiff that the hose furnished under the contract be the equal of the sample' furnished for test. This warranty in itself did not serve to extend the time or manner of inspection and made no change in the contract in reference thereto.
The Reporter's statement of the ease:
Mr. George A. King for the plaintiff. King'S King were on the briefs.
Mr. Seth Shepard, jr., with whom was Mr. Assistant Attorney General Huston Thompson, for the defendants:
In the case of Kellog Bridge Co. v. Hamilton, 110 U. S., 108, a bridge builder sold to the plaintiff the preliminary “ false work ” constructed by the former as a necessary part of a bridge he was building for a railway company, and the plaintiff undertook to assume the builder’s contract and complete the bridge. Insufficiency of the “ false work ” was disclosed during the progress of plaintiff’s work, the defect not being apparent upon inspection. The court permitted the plaintiff to recover the damages sustained by reason of the insufficiency of the “ false work ” on the ground that as the seller was the maker of the thing sold he impliedly warranted that it was reasonably suited to the purpose for which he knew it was designed.
In Pope v. Allis, 115 U. S., 363, where iron ordered by plaintiff had not been manufactured at the date of the contract, the court used this language:
When the subject matter of the sale is not in existence or not ascertained at the time of the contract, an undertaking that it shall, when existing or ascertained, possess certain qualities is not a mere warranty but a condition, the performance of which is precedent to any obligation upon the vendee under the contract.
Iron of a different grade from that ordered having been delivered, the court allowed the plaintiff to recover the contract price which he had paid before discovery of the breach of condition. So in Randall v. Newson, 2 Q. B. D., 102, the court, in permitting a buyer to recover the value of a carriage pole and such damages to his horses as were the natural consequence of the defect in the pole, said that the governing principle is “that the thing offered and delivered under a contract of purchase and sale must answer the description of it which is contained in the words in the contract.” So, also, where a buyer purchased “ oxalic acid ” from a seller who disclaimed at the sale all responsibility as to the quality of the article, it was held that even though the buyer inspected it in bulk and passed it, he could recover, because the contract was not performed by the delivery of something not properly within the description of oxalic acid. Josling v. Kingsford, 13 C. D., 447.
These decisions sufficiently indicate the distinctive feature of the present case. “ Suction hose ” that will not stand suction is not suction hose. The seller has wholly failed to perform a precedent condition; he has failed to deliver the thing he contracted to deliver. See also Seitz v. Brewers Refrigerating Co., 141 U. S., 510; Ideal Heating Co. v. Kramer, 127 Iowa, 137; Bigge v. Parkinson, 7 H. & N., 954; Cunningham v. Hill, 86 Mass., 268.
The case of Bigge v. Parkinson, supra, concerned a ship which was supplied with provisions “ guaranteed to pass survey of the honorable East India Co.’s officers.” Goods were inspected and passed, but during the voyage were discovered to be unsuitable for consumption. Plaintiff’s counsel argued that “ the parties agreed upon a particular mode by which the quality of the provisions was to be tested; and when approved, all responsibility of the seller was at an end.” However, the court held that the inspection could not exclude the implied promise that the goods were fit for the purpose intended.
In the case of Bagley v. Cleveland Roller Mill Co., 21 Fed., 159, 165, the court, in granting relief to the buyer of defective steel, said:
The defective quality of the steel received was not obvious upon inspection, and, as the fault was a latent one, their acceptance and use of it is not material, either upon the theory that their cause of action did not survive the acceptance or that their conduct starts the presumption that it was a satisfactory article. Undoubtedly, the plaintiffs could have discovered the latent defects in the steel here if they had made a thorough test by heating and plunging it. The question, however, is not what they could have discovered, but what they did discover, and upon that question the testimony is decisive. Acting upon the assumption that the defendant had sent them the article ordered, there was probably a relaxation of their usual vigilance in testing its quality, but not a scintilla of evidence to show or raise the inference that they were aware of its defects until after it had been used and the vises in which it had been used had been sold in the market.
That the defendants may use the breach of condition in reduction of damages in an action brought by the vendor for the price is undoubted. Lyon v. Bertram, 20 How., 149. The price agreed to be paid will be regarded as the value of the property. Meyer, Wilson & Co. v. Everette Paper & Pulp Co., 184 Fed., 945.
Assuming that the hose was not retained by the defendants for an unreasonable length of time before discovering its defects, it is plain that the right can not be considered as waived. We have argued that the fact of acceptance and use is immaterial under the circumstances of this case, but, indeed, there was no acceptance. Acceptance in law means “ the assent of the buyer to become owner of specific goods offered by the seller.” It is not to be confused with receipt. Where goods are of such a character that it is impossible without actually putting them into use to determine what kind of goods they are, then the mere acceptance of the goods will not constitute an acceptance in law, and the defendants will have a right under the law to go a step further, test the goods and ascertain whether they are such as fulfill the contract made between the parties. Whiting Co. v. White Lead Works, 58 Mich., 29; McNeal v. Brann, 53 N. J. L., 617. The question then becomes this: Did the defendant take an unreasonable length of time before discovering the worthlessness of the hose and thereby waive their right to damages against the claimants ?
“Reasonable time,” as Judge Downey recently said, is a term of much flexibility. The reasonableness of the time taken for tests depends upon all the circumstances of the case. Sheehy Co. v. Eastern Importing & Mfg. Co., 43 Wash. L. R., 708.
It can not be argued that the number of days which may have elapsed between the receipt of the goods and the test made of them furnishes any sure guide in determining the question of reasonableness. A gasoline engine can probably be tested on the day of its arrival; the foal of a mare can not be proved for several months; the fruit-bearing capacity of a young tree perhaps not for several years. Shearer v. Park Nursery Co., 103 Cal., 415.
In Phillips Const. Co. v. Seymour, 91 17. S., 646, the Supreme Court held that though the express stipulation as to time had been waived and the obligation to pay the agreed price was complete, still it was not so far waived that the defendant could not recoup the damages suffered by reason of plaintiff’s breach of his promise to complete by a certain time.
Even in Georgia, the only State in which express guaranties do not survive acceptance made by a buyer who knows of the defects when he accepts the goods, an' express guaranty will excuse examination of the goods even for obvious defects, when the buyer is ignorant of them. Haltiwanger v. Tanner, 103 Ga., 314.

Opinion:
Booth, Judge,
reviewing the facts found to be established delivered the opinion of the court:
The claimant company, a New Jersey corporation, made a written agreement to supply the defendants, through the Isthmian Canal Commission, with certain quantities of suction hose. The contract was the result of a response to a public circular inviting bids for this and other classes of merchandise. The circular described in detail the quan tities, sizes, and qualities of suction hose, and in addition thereto set forth with much particularity carefully prepared specifications for its manufacture and test. Among other specifications which subsequently became part of the contract, the following are especially pertinent:
" 8. Friction.—Hose must comply with friction tests as follows: A section 1 inch long will be taken from any part of the hose and the friction determined by the time and the force required to unwind 6 inches of the hose, the force being applied at right angles to the line of separation. Force used will be 15 pounds, and when unwinding the average speed must not exceed 6 inches in 10 minutes." *
"2. Inspection and tests.—All hose to be inspected at works by representatives of purchaser before shipping upon due notice that material is ready for inspection. Hose will be tested in presence of purchaser's inspector either at works or at such other place as purchasing officer may specify. If at former, contractor shall furnish all facilities necessary to make tests without extra charge. Inspector to indicate pieces to be tested as samples of whole lot presented for acceptance. With each lot of 200 pieces or fraction thereof ordered, one 6-foot length with proper couplings must be furnished free of cost for test."
*
" 4. Material.—All hose must be soft and pliable, made of stout, long-staple cotton duck, Para tube, friction, and cover. Thickness of tube and cover and weight of duck to be in accordance with table given for kind of hose specified. It is desired that hose comply strictly with these specifications, and to be suitable for tropical climate."
" Construction.—The plies of canvas must be frictioned on both sides and be firmly joined by distinct layers of rubber. The tube, friction, and cover to be of the same quality of gum. No rubber substitutes to be used. If reclaimed or old-stock rubber is used, the bidder must state the percentage of same. The compound to be made from well-seasoned Para. The inside of the tube must be smoothly made and free from imperfections and cracks, special attention being given to have a good job at the point where the enlarged end begins on short lengths."
4¡ «
Articles III and IV of the contract provided as follows:
"Article III. The commission reserves the right to make preliminary inspection of articles or materials to be fur nished hereunder at the point of manufacture or purchase and to there determine whether the materials or supplies comply with the specifications, and may at such times reject any such materials or supplies as being deficient in good workmanship or as not complying with the specifications; but final inspection and acceptance will only be made on the Isthmus after delivery as above. When required, the material necessary for making tests shall be furnished at the contractor's cost.
"Article IY. Upon delivery on the Isthmus and final inspection and acceptance by the commission of the articles and materials covered by any order issued under this agreement there will be paid to the contractor, at the office of the disbursing officer of the Isthmian Canal Commission, at Washington, D. C., as soon as practicable, provided provision has been made therefor by Congress pursuant to section 5, act of June 28, 1902, 32 U. S. Stats., 483, ninety (90)' per centum of the contract value of the materials or supplies so accepted; and within sixty (60) days thereafter, upon the execution, if required, of a release by the contractor of all claims against the United States on account of such order, there will be paid to the contractor at the said office the remaining ten (10) per centum due upon the full performance of such order by the contractor."
The claimant company manufactured and delivered to the defendants at various times under said contract 6,500 feet of suction hose. Each shipment was inspected in accord with the provisions of the contract, and no complaint was made in reference thereto until after the expiration of from three to eight months, when about 1,280 feet of the hose was rejected as being defective and not in accord with the specifications and contract. The rejection resulted from a use of the lengths condemned and followed the injection into the contract of a new method of friction test materially different from the one originally prescribed, as set forth in specification 8, supra.
During the course of the contract dealing the parties to the agreement modified the last clause of specification 2, supra. It was found impracticable to furnish the 6-foot length for test as therein provided, and in consideration of a waiver of this requirement in all its rigidity the claimants gave an express warranty that the hose furnished under the contract was the equal in every respect of the sample furnished for test.
The defendants deducted $2,537.20 from the amount due the claimants as the contract value of the hose rejected, and it is for this amount the claimant company sues. An obvious error, conceded by the defendants, is an overcharge against the claimant of $306.25, a sum .charged against it when in fact it was not the manufacturer of the hose at all.
It is apparent from the findings, as to the accuracy of which there is no material dispute, that the claimant company in the performance of its contract furnished hose which successfully passed all the requirements of detail of manufacture and test presented by the contract, and no defect was discovered until the actual use of the lengths of hose thereafter rejected by the defendants' officers on the Isthmus. The hose was first inspected by the defendants' officers at the factory, was then subjected to a scientific test at the Agricultural Department at Washington, and the record, distinctly free from doubt, discloses that it was thereafter accepted for shipment to the Isthmus. The friction test proposed by the specifications has in this instance a peculiar significance, because by its express terms it contemplated a subjection of the hose to a specified method of unwinding, which did not disclose the adhesive qualities of the inner tube of rubber to the cotton duck. The hose rejected was alleged to be faulty in this respect, the inner tube of rubber collapsed under pressure, and the scientific test applied to ascertain this fact aside from usage, as appears from Finding Y, was a decided variation from the contract test, and one distinctly individual, not being recognized as the usual and customary one by those engaged in the trade.
The contract provided for three separate inspections of the hose; the final one to be made by the officers of the defendants on the Isthmus after delivery. While the express language of the contract reads "final inspection and ac-' ceptance will be made on the Isthmus after delivery," there was no formal mode of acceptance prescribed other than the issuance of the necessary voucher in payment of the order, 10 per cent of the amount being retained as further surety for compliance with the contract. Nothing is said as to time or manner of final inspection, although it appears that all the hose complained of passed a satisfactory inspection as to external appearance and leakage, nothing being done in the way of a friction test on the Isthmus.
The contractor's obligations under his contract were succinctly stated and not difficult to understand. The defendants expressly provided for the exact kind of hose they desired, the quality of material to be used in its composition, and the respective tests to be employed to determine whether it met all the requirements of the contract. Viewing the transactions from a practical aside from a technical significance, it is obvious that the contractor, in discharging his obligations, furnished the hose under the rigid terms of the contract without incurring a single criticism or penalty until from three to eight months after it reached the Isthmus.
It is insisted, however, that out of the express language of the contract an implied warranty arose to furnish " motion hose" and suction hose as generally understood among the trade is a hose so manufactured as to withstand pressure without collapsing, and that notwithstanding the specifications this general warranty obtained. There can be no doubt that the defendants expressly specified " suction hose, 20-foot lengths," and if the specifications following the general description of the merchandise wanted had been omitted the defense would be invulnerable. It is more accurate to state as a logical inference from the whole transaction that the defendants wanted suction hose made exactly in accord with and from the material specified in detail in the contract. The contractor was not engaged to make suction hose according to his own knowledge of and skill in the trade. On the contrary, he was to manufacture it in accord with the defendants' idea of what constituted suction hose for the purposes of the contract. The tests prescribed were inserted for the express purpose of determining whether the contractor had executed his task in a workmanlike manner, correctly interpreted the specifications, and furnished the article contracted for. The case is quite different from one where the sale or manufacture of a desired article is attended only with the expression of its general designation and the known purposes of its use in the trade. If the defendants merely wanted suction hose, procuring it was a matter of simple formality, for suction hose has a distinct and well-understood meaning in the trade. In the case of MacKnight Flintic Co. v. Mayor, 160 N. Y., 72, a contractor agreed, according to certain plans and specifications, to construct water-tight floors, and it afterwards developed that, despite the workmanlike maimer in which the work had been done, the floor leaked. The court said:
"The reasonable construction of the covenant under consideration is that the plaintiff should furnish the materials and do the work according to the plans and specifications, and thus make the floors water-tight so far as the plans and specifications would permit."
In Seitz v. Brewers Refrigerating Co., 141 U. S., 510, the authorities covering this phase of the case are cited and the subject matter fully discussed.
Again, it can not escape observation that the claimant company delivered the hose to the defendants on the Isthmus in apt time under the contract. It then became the duty of the defendants, under all the circumstances of the transaction, to make the final inspection and return a definite assurance one way or the other as to its acceptance or rejection, and to do so in such time as to enable the contractor to comply with his contract, for a liquidated damage clause inserted in the agreement penalized the contractor for all delay in making deliveries. In fact, most stringent provisions in this respect, extending even to the annulment of the contract, were expressly inserted by the officers of the United States. It is a long distance from New Jersey to the Isthmus of Panama, and the transportation of supplies is a matter of considerable importance and time. We need not sustain an assertion by the citation of numerous authorities that some limitation obtains as to the exercise of a reservation so rigid and consequential, and that is it must be invoked within a reasonable and proper time. The hose delivered was, as the findings show, subjected to what the officers state to be a "preliminary test" and then permitted to remain in storage for from three to eight months before any objection was found. The contract made no provisions for a preliminary test on the Isthmus. Articles III, IV, and V point out the time and number of tests which the hose must undergo. These articles, both comprehensive and restricted in terms, were placed in the contract by the defendants, who drafted the same, and the obligation imposed upon the contractor can not be extended by their terms to such an undue length of time as may suit the convenience of the defendants. If articles of merchandise to be manufactured and delivered under certain precise specifications and subjected to certain prescribed inspections and tests meet the specifications, inspections, and tests, and no complaint with respect thereto is made within a reasonable time after their final delivery, the transaction under the contract is closed. It is the equivalent of final acceptance and can not be reopened because of failure to apply a test which could and should have been made in the first instance, which when belatedly applied demonstrated an alleged defect. Brown v. United States, 1 C. Cls., 307; Finney v. United States, 32 C. Cls., 546; Universal Trading Co., 20 Comp. Dec., 337; Carlisle & Thomas, 21 Comp. Dec., 150.
What constitutes a reasonable time depends upon the circumstances of the individual transaction, the nature of the merchandise to be furnished, and all the attendant incidents of the contractual obligations. Shearer v. Park Nursery Co., 103 Cal., 415. In this case suction hose, when delivered, is susceptible of practically immediate inspection and test. The findings conclusively establish the fact, and it is manifestly incontrovertible, because in point of fact the greater amount of hose furnished by the contractor under his contract was put in use and no complaint with respect thereto was made. The hose retained in storage was the subject of rejection.
The claimant company expressly warranted the hose to be equal in all respects to the lengths furnished for tests. This warranty was in all respects legal and binding and applied to all the hose furnished under the contract. The willingness of the claimant to make the warranty exhibits its good faith and in no wise authorized the defendants to relax the vigilance required of them under the inspection and test articles of the contract. It did not extend the time or manner of inspection and imported no new terms into the contract with reference thereto. The defendants, to avail themselves of a breach thereof, must, under the contract, assume the burden of showing a divergence in quality between the lengths furnished for test and the total amount furnished under the contract. There is nothing in the record to establish the same; on the contrary, the hose finally rejected was not subjected to the test imposed upon the lengths furnished by the claimant under the contract, and nothing whatever appears upon which a finding could be predicated showing a variation in quality in this respect. The hose was never put under suction pressure before it reached the Isthmus; the so-called preliminary test did not embody this feature; the contract did not provide for such a test; and, so far as the record discloses, there was no breach of the express warranty. It can not be said that the application of a certain mode of inspection and test quite different from that provided in the contract is available to show a breach of an express warranty under an express contract to manufacture merchandise of a quality expressly defined in the agreement. The hose rejected should have been tested in the same manner and under the same conditions as the sample lengths, or, if subjected to pressure as a method of final inspection and test, it should have been done within a reasonable time after its final delivery on the Isthmus.
The court has not overlooked the relative situation of the parties in reference to the subject matter of the contract. The disadvantages, if any such existed, were in most respects mutual. The officers of the Government, exercising the characteristic care and foresight indispensible in contracting for supplies to be transported a long distance, to be used under different climatic conditions, and for especial and important purposes, imposed upon the contractor supreme care and prudence in their manufacture and delivery. The contractor assumed this burden in all its details, and if he discharges his obligation by meeting the-express conditions of the contract and delivers the articles he agrees to deliver, no liability attaches because in the end it may not in all respects meet fully the anticipations of those engaged in its use. There is absolutely nothing in the record that remotely suggests the degree or extent of pressure under which the hose is alleged to have collapsed, and nothing to show the resistive qualities of the hose made in accord with the specifications as to size, thickness, etc. The manner of test which is alleged to have brought to the surface the defects complained of is described alone by the term "use." Where and for how long it was used, by whom and for what purpose, is all left to inference and supposed common knowledge of such facts. Some degree of carelessness prevailed, for in the condemnation this contractor was overcharged a sum for hose it never manufactured or delivered, and which is admitted in this case. The contractor received no intimation of dissatisfaction until months after the hose had been delivered. During this time claimant received repeated orders for additional hose under the contract and at least two additional orders outside of the contract, all of which it furnished from time to time under the positive belief of satisfactory final inspection, test, and acceptance. The contract expired by limitation on June 30, 1910, and it was not until some time in September thereafter that the contractor received notice of these rejections, although made previously. Orders continued to come in for additional suction hose made under exactly the same circumstances as the rejected hose, and even after the same had been rejected, both under the contract and independently thereof. Under all these facts, can it be said that the contractor may be indefinitely kept in ignorance of a serious defect in an article at least apparently approved in every way ? Most assuredly the defendants must be held to an observance of some degree of reasonableness in point of time and be not permitted to constructively at least lead a contractor into the belief that his goods are acceptable under the contract and will be paid for.
Judgment is awarded claimant in the sum of $2,537.20. It is so ordered.