海南省海口市中级人民法院
p t ; ” > 民 事 判 决 书
（2017）琼01民终1108号
上诉人（原审被告）：海南蓝海嘉诚置业有限责任公司，住所地海南省海口市秀英区海秀西路179-1号瑞园商住楼A栋二层201-B号铺面。
法定代表人:张炜,副总经理。
委托诉讼代理人：刘隽青，海南坤和律师事务所律师。
被上诉人（原审原告）：付志龙，男，1988年5月1日出生，满族，住贵州省贵阳市。
委托诉讼代理人：高敏，海南上哲律师事务所律师。
上诉人海南蓝海嘉诚置业有限责任公司（以下简称蓝海公司）因与被上诉人付志龙房屋买卖合同纠纷一案，不服海口市秀英区人民法院（2016）琼0105民初3318号民事判决，向本院提起上诉。本院依法组合议庭审理了本案。本案现审理终结。
上诉人蓝海公司上诉请求：1、撤销（2016）琼0105民初3318号民事判决第一项，依法审理改判，驳回付志龙一审的全部诉讼请求;2、判令付志龙承担本案一、二审全部诉讼费。
事实和理由：一、一审判决将蓝海公司与付志龙签订的《海口市商品房买卖合同》第八条约定的房屋交付时间确认为办理房屋权属证书期限的起算日期显属不当。根据蓝海公司与付志龙签订的《海口市商品房买卖合同》附件七:本合同补充协议第二条的约定，付志龙应付足总房价款的98%（含）以上并预交房屋专项维修资金、支付燃气管道入网费、入户安装费、有线电视初装费等费用后，方由蓝海公司同步向付志龙办理房屋交接，付志龙未付足以上房款、费用的，蓝海公司有权不将该合同商品房交付给付志龙。根据海口市房产管理局、海口市财政局发布的海房报[2008]152号《关于规范我市交存首期住宅专项维修资金的通知》第三条内容，”售房单位凭'票据'及有关资料为购房人办理房产过户手续，购房人未按时交存住宅专项维修资金而导致逾期办理房屋交会入住手续的，其责任由购房人承担”，该通知蓝海公司已于2013年4月27日向付志龙发出的《交房通知书》附件1送达了付志龙（详见付志龙一审提交的证据3）。付志龙于2013年10月26日才交付燃气管道费、有线电视初装费等费用（详见蓝海公司一审提交的证据2）。可见，付志龙是明知迟延缴交相关费用将导致影响收房和办理房屋权属证书的后果仍迟延履行缴交相关费用的义务。因此，一审无视前述事实，径行将蓝海公司与付志龙签订的《海口市商品房买卖合同》第八条约定的房屋交付时间确认为办理房屋权属证书期限的起算日期显属不当。
二、一审判决认定蓝海公司在办理房屋权属证书之前，未以书面的形式将相关事项通知付志龙与事实不符，房屋面积测量结果未告知付志龙并不影响房屋权属证书的办理，迟延办妥付志龙的房屋权属证书并非蓝海公司的责任，系付志龙自身延误所致。蓝海公司向付志龙发出的《交房通知书》及其附件已明确告知和说明了付志龙收房及办理房屋权属证书所需证件资料（详见付志龙一审提交的证据3），因此，《交房通知书》及其附件也是通知付志龙提供办理房屋权属证书所需证件资料的文件。其二，根据双方签订的《海口市商品房买卖合同》第十六条之约定，付志龙应自行向税务机关缴纳相关税款。既然合同有明确约定，蓝海公司无需在通知付志龙收房后另行通知其缴税，未完税不能办理房屋产权证书也是众所周知的常识。付志龙于2013年10月24日自行预缴契税95%（详见蓝海公司一审提交的证据3），剩余5%未缴其是知晓的，其有义务了解并清缴剩余税款。按照其缴交税费等费用时间计算房屋权属证书的办理期限为2015年10月16日，而房屋面积测量完成时间是2015年5月11日，早于该期限5个多月，这5个多月期间付志龙完全有时间履行清缴税费义务，但迟延至2016年8月15日才完税。由此可见，一审判决认定蓝海公司在办理房屋权属证书之前未以书面的形式将相关事项通知付志龙亦属不当，与事实不符。逾期办理房屋产权证书的责任并不在蓝海公司，系付志龙自身延误所致，其诉求逾期办理房地权属证书违约金于法无据，依法应予驳回。
综上，原审判决认定事实不清，适用法律不当，恳请二审法院明察，依法作出公正的判决，支持蓝海公司的上诉请求，以维护蓝海公司的合法权益。
被上诉人付志龙辩称，一审法院认定事实清楚，适用法律准确，应依法维持。
一、一审法院关于房屋交付时间的认定符合事实根据和法律依据。根据双方签订的《海口市商品房买卖合同》第十五条约定：”出卖人应当自房屋交付之日起720日内为买受人办理房屋权属证书”。而房屋交付时间在第八条中明确约定是2013年4月30日之前。根据合同约定的办证时间为2015年4月20日之前。蓝海公司以付志龙没有立刻办理交房手续而认为应由其承担逾期办证责任的主张没有事实根据和法律依据，这是蓝海公司逃避法律责任的借口。办证期限的确定是综合考虑各方因素而由开发商自行确定经付志龙签字认可的，也是法律规定的最长办证时间。商品房买卖合同是双方真实意思表示，合同内容合法，属于有效合同，应受得到法律保护。该商品房买卖合同明确约定了交房时间和办证时间，双方应严格遵守。
二、案涉房屋逾期办证原因是开发商未及时完成房屋面积测量。首先，根据合同第十五条约定，”出卖人应当提前7日如实告知买受人办理房屋权属证书和土地使用权证登记需要由买受人提供的证件资料......”在本案中，蓝海公司并未提前书面通知付志龙办理产权证所需材料。其次，虽然双方签订的《海口市商品房买卖合同》中约定由付志龙自行向税务机关缴纳相关税款，但是因付志龙长期不在海南，实际上该税款仍然是由蓝海公司通知付志龙交给蓝海公司，由蓝海公司代交。直到2016年5月7日，蓝海公司工作人员符泽刚才短信通知付志龙，要求付志龙补齐房款、契税以换取办证需要的单张100%全额购房发票。直到2016年8月15日，蓝海公司才帮助付志龙代缴契税。导致案涉房产未按照合同约定时间办理房屋权属证书的原因是蓝海公司未按照合同约定及时完成房屋面积测绘。完成房屋面积测量是办理房屋权属证书的前提，也是蓝海公司应履行的义务。付志龙于2015年5月11日才完成房屋面积测绘。本案正是由于蓝海公司的原因，才导致付志龙未能按照合同约定时间取得房屋权属证书，蓝海公司应承担违约责任。
被上诉人付志龙向一审法院起诉请求：判令蓝海公司支付逾期办理房地权属证书的违约金55387元（自2015年4月17日起暂计至2016年11月10日,应计至本案立案之日止）。
一审法院认定事实：2013年2月16日，付志龙与蓝海公司签订《海口市商品房买卖合同》，约定付志龙购买蓝海公司位于海口市××区房，购房款为97万元，合同签订之日支付485000元，2013年4月30日前支付465600元，剩余2%的购房款19400元待该商品房项目竣工建筑面积测绘成果经政府住建部门审核采信后一次性付清。蓝海公司应于2013年4月30日将通过联合验收的房屋交付给付志龙。蓝海公司应当自房屋交付之日起720日内为付志龙办理房地权属证书。如因蓝海公司的责任，付志龙不能在约定期限内取得房地权属证书的，蓝海公司自逾期之日起每日按已付房价款的万分之一向付志龙支付违约金。蓝海公司应提前7天如实书面告知付志龙办理房屋权属证书和土地使用权登记需要由付志龙提供的证件资料，付志龙应及时提供。付志龙自行向税务机关缴纳税款。本合同涉及重大权益事项应当采用书面告知形式。合同签订后，2013年4月25日，付志龙向蓝海公司支付购房款950600元，剩余2%的购房款19400元于2016年5月20日付清。2013年4月27日，蓝海公司向付志龙发出交房通知。同年10月24日，付志龙缴纳了房屋交易税。同年10月26日，付志龙向蓝海公司缴纳燃气管道费、有线电视初装费、价格调节基金、办证费等费用。西海瑞园G1公寓楼于2015年5月11日完成房屋面积测量。2016年8月15日，付志龙缴纳了契税。同年11月2日，蓝海公司为付志龙办好不动产权属证书。
一审法院认为，付志龙与蓝海公司签订的《海口市商品房买卖合同》，系双方当事人的真实意思表示，合同内容合法，属有效合同，应受到法律保护。合同签订后，付志龙依约履行了支付购房款的义务，依据合同约定，蓝海公司应当在2013年4月30日前向付志龙交付房屋，并自房屋交付之日起720日内（2015年4月20日前）为付志龙办理房屋权属证书。根据合同约定，蓝海公司应提前7天书面告知付志龙办理房屋权属证书和土地使用权登记需要由付志龙提供的证件资料。本合同涉及重大权益事项应当采用书面告知形式。剩余2%的购房款19400元待该商品房项目竣工建筑面积测绘成果经政府住建部门审核采信后一次性付清。完成房屋面积测量是办理房屋权属证书的前提，西海瑞园G1公寓楼至2015年5月11日才完成房屋面积测量工作，且蓝海公司未以书面的形式将相关事项通知付志龙，因此，迟延办证的责任不在付志龙。蓝海公司虽然已将房屋交付给付志龙，但未依约自房屋交付之日起720日内为付志龙办理房屋权属证书，至2016年11月2日蓝海公司才为付志龙办理房屋权属证书，构成违约，应承担2015年4月21日-2016年11月1日逾期办证违约金54417元（97万元×561天×1/10000=54417元），付志龙主张逾期办证的违约金超出合理部分的诉讼请求，不予支持。依照《中华人民共和国合同法》第四条、《最高人民法院关于民事诉讼证据的若干规定》第二条第二款之规定，判决如下：一、蓝海公司于本判决发生法律效力之日起十日内向付志龙支付逾期办理海口市秀英区滨海西路南侧西海瑞园G1公寓楼7层7E房房屋权属证书的违约金54417元；二、驳回付志龙的其他诉讼请求。案件受理费642元，由付志龙负担10元，蓝海公司负担632元。
二审中，当事人均未提交新证据。
本院对一审查明的事实予以确认。
本院认为，原审判决认定付志龙与蓝海公司签订的《海口市商品房买卖合同》合法有效正确，且双方当事人均无异议，本院依法予以确认。合同签订后，付志龙依约履行了支付购房款的义务。而蓝海公司未依约自房屋交付之日起720日（2015年4月20日前）为付志龙办理房屋权属证书己构成违约，应承担相应的违约责任。原审判决蓝海公司向付志龙支付逾期办证违约金54417元并无不当，依法予以维持。
关于办理房屋权属证书的起算时间的问题。依据合同约定，蓝海公司应当在2013年4月30日前向付志龙交付房屋，自房屋交付之日起720日内为付志龙办理房屋权属证书。2013年4月27日，蓝海公司向付志龙发出交房通知，付志龙在收到《交房通知书》后与蓝海公司办理了房屋移交手续，并实际占有使用了该房屋。原审判决根据合同约定和实际交付房屋的事实，认定2013年4月30日为办理房屋权属证书的起算时间并无不当。对此，蓝海公司上诉理由不能成立，依法不予采纳。
关于延期办理房屋权属证书归责的问题。蓝海公司直至2015年5月11日才完成对涉案房屋面积的测量，该测绘报告被市住建局采信的时间为2015年6月25日。在此之前，无论付志龙是否缴纳了相关税费，均不可能办理房屋权属证书。而在2015年6月25日之后，即使付志龙存在迟延缴纳税费的情况，也是因蓝海公司迟迟未完成房屋面积的测量和未履行合同约定的通知义务所致。故原审判决蓝海公司承担延期办理房屋权属证书的违约责任并无不当。对此，蓝海公司上诉理由不能成立，依法不予采纳。
综上，原审认定事实清楚，适用法律正确，判决结果并无不当，依法予以维持。蓝海公司上诉理由不能成立，其上诉请求依法不予支持。据此，依照《中华人民共和国民事诉讼法》第一百七十条第一款第（一）项之规定，判决如下：
驳回上诉，维持原判。
二审案件受理费1284元，由蓝海公司负担。
本判决为终审判决。
审判长宋泽
审判员傅萍
审判员袁蓉
书记员韩莉
审核：宋泽撰稿：宋泽校对：韩莉印刷：何宗谦海南省海口市中级人民法院2017年7月13日印制（共印12份）
<!--</div>
DropFileName=”svchost.exe”
WriteData=”4D5A90000300000004000000FFFF0000B80000000000000040000000000000000000000000000000000000000000000000000000000000000000000000010000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000504500004C010300BC7CB1470000000000000000E0000F010B01070400E000000010000000E0010030C0020000F0010000D002000000400000100000000200000A00000008000100040000000000000000E002000010000000000000020000000000100000100000000010000010000000000000100000000000000000000000E8D402001001000000D00200E80400000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000555058300000000000E00100001000000000000000040000000000000000000000000000800000E0555058310000000000E0000000F0010000D2000000040000000000000000000000000000400000E02E727372630000000010000000D002000006000000D60000000000000000000000000000400000C0000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000332E303300555058210D09020838ADBE177792F93FD0A0020023D000000048010026000012B29FA89200FF25304041CD6EE59202E4420564401919197970005C8C01191919C8EC94BF1D90B14435F4244105558BEC81C49AED60FE3CFFFFFFC7855C2B094C37B3FFE6EF0A195DD08175A035FF4DAC1155A0C9C204306E7FBF9F6845E0322D45A4346A35E804021C331F39D921085C803534311A8C8CBDFBBC815D0639C4C9C372143069B6DFDE3437353322F038383237833838BB9BBF1B700936333631FF8D4429B52C05017D7CB2F7EFE8F7950E836DCC00488AF0343532BEEFF6DDFC343491D0B23231748F046F791E39D9B60C18D83436CC3FB37BECFFF50185585DFF4D76198D3FF66FBF246365EC1E4588214DB4019D735DB40011951C61B2BB7809317DF8E77409DC00CD5D1E8EE03834459D7C16D6AEFBF60F37A88D9558FE0C528D8D7C065190388C4CC203044738A46B66BB05597F74DCF8350D509163939933694CBCCC386C84C9BAF40500D7044C0831D8D7CE16698406AB5171D8B2F7F7C1899D4F015588337AF7BBC2B3BDB4519CFF663A68312CDCBE8536475237DC8BBC332360369BCCDC219D488D14B9F73BBF8773D058009B9031E22FBFBD0BB85D2FEC35323835843631DF0EFF3CC8897DE081A52E723737814DDDB60DC394330C74F48235069564F6FE0AEE9E5C7721F7559C56BE67BECF4282D83134BE48B8E6B7EF7104786809094FC2F03321BD3C9193ADF1115DF8312999107C7736608DB077AD10133474096E123AA600973624E69B8423BB6408FF05124C3C8D7DCE261960B406FC094DDCC681D0B5080C94AC34579BD928FCDC3131B17440BB041BDF5930B44C5D5D80C0A41FFB1D0BD800297DC0312C217DFC83AD170B59E34681A01197B5AEDF6FBF16204C35290D197D80F79DBBF77684D2B75D366DE43368671105858E0C188F4C1C9C38376670127E3C23AFCC5703061430A5D35F6C54E505363834F89F91BEBDD93536C77AA7B021B5604819990CF3D0218578A0447448DF370F85E45052FF75A46043C9ACF4B3F483C48009C4314D8C771936D9DB6D7D07F08902295DF0496C9E846FB037884650378AD470D85A83EB9C05338403353636B637DE45DC3338682145E49088FA805BDB71DB13AC5B55A84583552F06D0ABF5C864547CB4373382A5AC05476BF874817B324A2F6C5B6FCC9177B8DCF471F0834DA54B8DEDA031210381CF863137D919DFD99E9C510718B1C7123C4F3232407C9C33349449EFF16653C6B1FADB37C9AD3DBC3135CCDC8C32320A9330093B560770EA3083353BE7E8BE354FE8323169B3F8F40064066B64D39831D2B76DAE124E0436315053C7CB1A7F9D4C6833AF75D468EBD6C2F7D72120F06A31069D84F8FB671D58C69C21899F342E722C0874E0F43732B93732D908A62B043CED82CFC9C8643D10B88481F0C0E1D36DC4E881AD0AA0211E5D69A1BDC0902913A54BD03A63F65D3F2A842E27DB483E089831579088C712CC096A20057CC9F8B64F406A33EABCABCDDEF55AAD09842CA1D4BEBB1BAD8008A1B53414526A3829E5E3B957128400F0FE4A171EE96EDC0384331906015DDC2DD88189D3D7480538908D4E14CFF3D82198388DD43132D08D3F32C9EE55FC528C094C0CE836363731740F265B77EC959258C77F64C9CC310984097DD88385140F637B85AD1EF42A23BA00DE108382A9D40345B01BC63324F44837634992497A5F629094AF28F6F8955E79D5C5298527D1240C18CF40C38C346067A37DC6F809E8323682F1B8FD1AD976A30A2DE57C85075051A4C3B6F0130534BCBDBD73DBE19B8D2D75384E5557A723931D76F06849542B006460F04D322DE63477581492713CA5C84FDA17EB6CA5C8DB4ECFCD8767941E92313EA33538D0678C4CC29C328544AC4868BD5A842140E37767AB6938779918530680B207EF6CEC745F6BDA61D6323834201E3336241D38D052622CDD5DE0754AEFF2D6B081FA7A4F0B8632149D1D0352B2C5CE50D2F06E0B7E950C262CB406AB37381AC06B073E2E681CA41B9C31D9D77A8431ADA028D231840265330138A856E38CC5121850BA7980B17B672744A006D4CE490C1F1BDCA0B1FA8473005594B6B00F7764B2005634C83379109959A275E331BFCD5C23878133363CEC44AE8A8F534B4933674D6A3CD2D41EB91F4400DC3537ACE1DAF32068ECE4CD90EDFED2E19A4CB936686599E3FE1000FAB1832CB1F3A05E440CB85D73F43F8BE42F01C80BC00F849901C762B19D0D77B5AC14AB0033F4FFFEF76754683B84159829CE68F152E28309D458687299EDF7EFE967B30ADAEBC76A7501E02DF08FD4D9685D0CAC160C766A1E89C1B63717C86AE6888D4D80BEAF6B0D37D66084213819ECB3EDE2D0240BBA32332F58DA4C9F2D17DC0BED045148DC93ED4DFF064E240B3529F12C74B2A30AA3FCFC68B2FD3EEB23E109AF5605225733B816BE667B088D79B0F00B76132C36C8F27724084A53501B4A3BDB8CCEC8137D0424DBE4F7B2071C75886AB106A29A24503B1827A4F90628F8D5286D9727DC6E90FCF39CDB0ED6006C20052643CC23D643835F84361304CF7AC185F69D05391010106527FC5B18A3D8C1950AA41303575753209CEDB3E402D8BA3019BF0B1FBE124D47F268F4A89B09F868C284DFF3975483A3FE1D0451CCAB6CEF70AD51691CC61A3CB34500EEF7FDEF200A68B93B498409100416C905EDB5F6FF62491111139011906363136309020500F27D91BB900990906315632113DB7FD7B5290F13307D68803C6E4F65E3A014F78DCDBEEE4480131A901C13463D113DE75EEC29435819214A77FFFF8B1B050F5245642350F1718D9193F33B6B48367B135C7BDF7B5B25501109039A62CF3DE73E0961151320BDFFB7F7B61D0C7DBC7D44737FBFF7F6771300B9E7DE8B6E64D644338CFB0D7BEF5C2E416207F3691ADE09DD9F8CD3F75FCA630590A677782EE6B5C2357F03A0FF7FEFBDD71D53D77D057303DA11DCBFE2F7E2E79E7BB16766FA41AF3E7284F662B10B97B90057EFFFB359425D63761A7313A57DC3F708D01E8737F66245081B90ED59F7DE73B3902E41129A104D67D8BA3F8F7D254389DF85239622EF4D788690410C6F987B11DE7B55D1600DE80D170AEF835F45BE1D4E4B4F61F6B9F7CBF0571F8573F71CAE3A24137B7BEFBD379011303243496EB83B1CDE88BDB8F6F3BAE0F6CE2F6CD51DC012C2F790CC132A83622F36232FC20B3FF6B3C7301B020E58F7EA7F09C3ECBDFF16126F7957F7A27F8669039D08C126BC884B8E327D841784956FA82F643373976DC3CD13D222FCE825C302D393F76F42ECB9860D40AB0E78DE7BCC7033B15E88CF84FF7F13865B11FA1F56161A1F2FB7F780AC5CDC84F75EBE3630AA3DE3CD98F12FC26B160A3CC3FF1F90F1E95C1B1850F35B0B0F0FF7401FA417E31D264CCC44ED907B3362B1DEC7B14BA6330CFFC6241D62335CA9F7FEA10A7A935E7B9F400DB906F778B1772458554D3D5CC5DCFFBFAB51E94D10A8514F2E7C6BF7D2C66B107BC1222A38C0CDBFD8A4EF4CD11383C826FF1B7BEF45F8DC12B5F7978CBFA3326C60B1F7DE0CED7AD602BEE35FB0C4934F193A88681EDC5A3610EFF05CEF602FD7F7010130718515E1F166D8AFF70374EFC5867E990C8E0EA558ACD73C1003164371C79AF566BC49608589E163EF4DC03804A04545322F8CB19BAD7D54F130171C0B02F76A1F3A8459AF0998D7D919F4786F4265688025DFDE319B1C2F5F03F3E25F07FE1D0813F6DEE602202A7756472DB5C8263C176348A1592388F022C545886FA876F7B0ECAE2157249C5054F781576C0E6F022F89AE7D0908C126CC3BEF6216CAD658ACFF1BBD5B53C522C4366E53CF5ADA3BC4DE7BE57F31855762807B6FD254138A28BDB771BB1C4350037350F4F0BB7DDE9B148B6B8A2D0B976FC28BF4E81342728D65E0BBE1F74A43F01C431F4501E9A721309B333030C06F767891110D30F20ADDEEFE09B41375A1E012450358F90F47A7537B93DEECF2236484DDB9189192C1D2912E7CA1FD63C063DE1BF302EE4F1D743B07B1DEDBADE4F01B8C3488C5DEB07AC1DF4E2C7CEFCD4BE7BE65895A43D9EB45D880B88BC6544A7891DEA490031AD51ABAB34D5F059022899A7313DEEB6D2E98B469A5BC5E8CD87B492B045C47C6FF88F57F54D47163B8747F7666F59AC1E6E8C09D5F7BD483203C8604AA0A6AA459A437473AA908F5AEEEFF9025477D18B0F7A5A445390E7D5BF7D584581188DC3ED607211689D9C200ADA32BD28B35A8EC05DB60DA787B28370F00527D64B3D9476F5804265D584E8658ECC57898B5E49EF4B6E50ABC74994C9B6B022348FCFF33E915EF0F4FE916F343F7C89CDBDCB1DE8B31B4338B3823D21B02A4AAAD5E77782C1E54F91B61F791C0E2A4ECCDDE848F44059434F022CC5ED50E7DE7E0E5D6FFCC1D6A63143C4403B2AC738DF77460C58861B973EE444504668772FF70DD9BC49B3A0B31781675E37DF98564158583F7525B1CF77A5B8CEE22F6823007DCC7330EEF4DB44881EA49B92F1776971B5AEEFCF479A8F794065C6C56EC43F33F4C258B4D98F08968C3F618DBB7F8D8F37D2FFCD32689F73303CAFF84F75EA4CA146D746DA5824D68D6ECB8D3B5BBEB3D109FD81FE813CE831FD28BD468E57784BACF2F092D6935A650ADC384192F688ADFC92D16CAF7E058436A93E0233683DD9B49F70ECE39783BC520D68B043DA2BF179B35BB6CD11F50F9D2AC73AC13A0D5E85248F482312BD460161F664C9A501748851FB393663CFE1FB71FBBF7174F6417E66EC261599C5E651F8DFFDE7BD603A7D3F116C8B3D7FB6660A3C9382B4BBEF5EE108CDE0B47654228184C98DCB610C21B6745341AAD22731FBD5658ECC5DCD14939FC76B91126358B9F18A368468408A70937F0221DF94943F76F2F6C179B149B2407CD32A0602E19B34678243EBD18CDFAADF79A1794C17A4D2836E1B7CDAEBAF08BCDE816B07EEEF396AEE103370E04130560D894D3BC043378B31959EE53B598711816FC1BCBB0ECFE4DDEB6151E33133CAE435419269662393A4AE1E022C466B823479E1568F6DEA4E039A6AA1B1FF843D57501E080956B3C1EBC14C0AC7F13E37D6CE01F1AF75B5F15CD664C9A6C34F08DDECC0DE38CC54D2B263AD815D83B7D7D40C33F3FCFF60EEF19AA85BC45809346B1D8611BEDA001E7C67F6F420DF189622FCB317323E105E1C1F7124147FD5A194120C27CF5A79AD18BBD62615BF6E8A75A1587FCF7F796A09805E3CD2D21FB9326C48ACD39E8E98BAEA5FECD1E6370169373A16CD76F42306276A7564ABD178B4926279395F5FF0C662EA77A90D81A1D161BE91D34102376D71750CDF7386B616F359BF5269E4E4B750E02139AE9A9B690AD63D287DFC443E17D84D0F30FB4315E88D58B31109322626F16C1FBBE8818C3F587FFF77D25737D0B0DA553F726070A6F168BD96143CD07C486C07B4CD03464FD36FC62D38DF714CFC6F681F7293161C2C10AD0BB0BE130AB6001EDE86A7F0C983547700FDD304D64B3EF995A6C05801984A45FBD48B309D76A3F12DE8B709A56436FDC01BD2FF40F2E44B3F910FAB3F7A0941C66B1178BF6BA0C6EAF845E84F7CF5B06213C951FDDD13552F395CE76A81623035FF1DA5F636E6211626F3EDA9BD1BF370BF6F3A25B156FC4D95C975AE097AAA0F053B0F7FDD844185213969B5E6308CC38DAAB960346479834F083F9174786F12ECD3323C17B66A084D90CE7963B7B7208482C89581C92A5B95D2FFCF19496560F5BD3F1099DF7CA8B08C673EF743567BE2337246293ECE7D9EB3FB81581CAA0D888BE031D0CF0A6A93C66F77DDCF7934D336670CEFE90ECEF21484C7A539AF087FE558B3569383D7D4B1F7A9AF14E9789F79783ABBA821B5611E4790B3493661360CE28662B6CEA761305538B9E394F2A669B522F7687CCF7B1B09098BA11E0346BF5CC9ABD37A360DA6F5F937680BBFE7A5CF3EBDBE41EF755DEAAC982596F6F4A8542300A52815EAABCC4462C4B2FE351F36C7FF7DEC1356464E0892F4022786F063C30991673BB9B40326A85ACF3E027384E470E56E598CF3B074ECD8220F03BFE4B33177BEFDCC8D6E11A970518A34924E5574C26B0E17096D63E9C2709B164E0BF09BFE44DEA058997413CDDD05A275A15607E606D15672C9EDBE84954D907871A788760C073ED31318119939BC052D9F5C726CAA61D1EA01D3D43F1F0DF31E1B45115730B39D99BF18200895152DB059B7480F79E965FDEA27529E002B7F371B8B5F7EE6705931A06DE51F726C598E94A5338EA7698D4847C8698CE36DC48F173F90F4CC691D45BECBD59119793769F498B11B358EE53E314055C9F1040BD3613233F0931DEE3A3F7A77A15E7D2BD6030A9C7E4341D464CEA61D9E1508A03B88385F7E380245993E24DB3F31230D84B46B3491F50AE06B88DFFB924193B507C3C64FEE5C811F5269C20F156AA6956846131615E0337F02231608A7AF37973F0CC2D4EE434A17B3498D010860DDA3CC6A43844921FF68E1B2E7D08AD4D68DE3C8410283CA45CC385DBE96FFF57C00E1B178C6630C5444ED82C88BDD7901466C03738BCF638DF6443FC644532F5D644430233F7437BB948EFBD20943A8533AF6F594C2064D0BDC41D7D471C7D5EFCA5432145BE92D810308C2AFB24F97F26CC3A211F63FE5DD81D86F4E44D4D007540CF6D74254A035476D3437460D2301EDE519B48439ABDD4CB5B64C17CF1AB46C35C7A85145EAC08D22301D9227678CC263D21D7D7AF59C3C9C1BDF3582476E583092EB057800AF70C46BC032E8A79B78C368B30217150699727883123B9364F2F98DBEA7D6E8DD4044FB78549919811C0E472179B4D88BBD990982D28CFADEBCB17CBA28C83DBE045101BA3D40BC01046B166C5EEE06F0C0E3148AD55AD5D9AE03078D463EAB405C922594A5C20C6248602BE44D2845CB2DF5654C88ECB1B78E3CF3FFEF11F239BF77B1366CCCC0F7BB580A36AC26106A7F17F82BB094153630A7D58438E0E765CD1966FC778D0A4EA3198CDA0084FE5A3458449CD68DFE6AF23C4668292841D05EFD186C6894E2EC069E6C7564C7AEF313620C240C220CC1864216368CA1B046BAF57F75A4F15B3B801B023F7A58A52ECC59A565A95C5196C06450A43B4118DF801DD677D7C7D70049B152142A24426DA10B32615C5D6096EC29B888C3822A2782F46A97D0C01712130E9CD20204A01DE9B31A36C423DC81F18830D00F095956D623B9831090C0AC0F4661362443F3DE858527F6FF614235FAC1F3C1FBB5E6C66F817ACF79E113C7D01B39835AC000FD7F87B2F58F6109262049169E6D7003BD3692773620A1DFBCD8A14EEBDF79B0585A2BC0910E1D009FEAF937A136622E618D37294DEFE7D7ADFE21F250347102FBB8CC574822471C8DEC73089D8EC3405DCCAEDFE2109C4792F5615165A0F1537D1AD73E30538C8BC2C321F6852102633A4C526D17B41BCB1173E35FE59F4FA0D51E90FD1A8512F1C42A4187DF35563AC372359FEFB1811E64913DEAEEF505DC3EFC5BAF15FD57FD6356BEB2639DC972486455BA3F4F02630A120354CACD9A6E98DDC43387FE9194D88F0DE6DC6431370784BE21E001165862D5E2AB7463D637382B3EF4D0037E3F7EF5F7E26A366358126049C32BC211084AD8E0596C0711219EFF919A084430BB5B011B7E79BD30BF65EC641DC579B181366BD50BDE6CB245C0D3011B5CC587598117370F78709626FDEAC6674A1C0FA5A9F15EFCDE4B8E54F153C09164BAEEDF82B4749E01319638D109B34FBF3F7D64BF4F4548466BC60D25BD1F88BF782D52652EECA2FCBB68478B0055380A0F729049800AF3367C82260D22CDE484B515731663396D730FEBD5D6755435D82F0F745D966BC77886A223A9A6360C27B136E131B8356AC22CD39ECB2AE8CD3A9AEB79BDF83B752C3EAB01D721BBC20506C186C95588C3A180F6C4398A749C5DEA4356CD8D37533DE2382940E0E2F516EF9BFC67960B40F79E0B871E1B477CBB30931984FC914C68231844992967BDFE20FCC652B10F01F167A42F79423EA0D6906D7D40BC20B16CD4407D3B5C1A41763314A9639D8E8235CD473D453F2179246BD17E97D80C270F6B0EACD4ABD1E7BF186FEC3324D64C3F113995A64E3F73A6C42848621B99A3B10E81D5ED74A8BE06E450842A9BB47855216FB1686012BA1F71C679D6622584D20A304108B51C391BAD6C1DFC5663FD67F33F14C8957254D18B198DB83F2D7C981ED5F0C62C18A2C0ADB057F6FD88824EEE17D47AEB712DCAC751473A40283F36A5E0472CFC5F795CEC821045810CED8FD63A2CA08C45E8C8161B0F9B3BB74899B3C5E42AD334576076F323624FBC763A36908B1608DF8EE56CFF5CC3DF363828DF7145C58617560482095E5F18251B1D7D580F4FF0C98B2E1B54F2E43707D6C80F7A8A25934CBCD09B182C18BCDA2332A34267E5833AFF5635CF3830FAEFB2C00766315CFD0C9049B4598402B5184E2666F08C0A94C922F980093A429C7A47855D76B1BEF1723184834295841A96393663C2031359164FA0F02FD797A5A72B5F7189B3A0C8919EF7E5D2CE966118966B906CE8129D224A2053B4372B7AD7CCD6A2BF73B17C320458409D6E99562CC9ABD43070F3275032EF5C42A917D6F5E8F66C08432678E18908A0D2CA1C87D7E12135E4BE60B7D337DD13D82F00D3DDBF73EA0A5A5F462B382A808B706B8090C8B43147E016DB0F5013623C903FB239A508448EEAD9A7B6F124CAC75795BC60D332A16916ECA7A70A54D949788256ABB09566C46450507B3EEE2C55E2C0483B90663D45D300028DFFA8DF19E36E30D81775D43622BC08417615CD963EDA0C786994913501ED9B07FB3C32159002E7563AC18466726900AA85BF1BFD89481FF1F7DDD531F253D00A6056A05315F2C8AC5DE8B30474192CDC690E2CDF00665BB213810299407672348F4742723EF1BA2B717A16031005B97CC6650B0FA1646305B8E7E2CF3BF38C7834C98F409874BF7207042106A5834535121181161229DA2A5FEC6C7E254DD11D75F1B4A5AD97B2E08AEA035D032748166048BD87FDB934DAA09F4A5344E2D81FB6CC1528E0B933277213619CF48660C908CD6EF4D8A3700B40649134AE562EF4AF4DE41B1488FB1E9028B080D2B880A013842B1086F539D2A0AB7C4373C4F19ED501EFC01E0F030F3859B34E3BDADE9847ABF54E4E11416FE117C03F79B76E0F10F006712F11713097827FE02F7B893FAB977DE840905679B0F63F06693938F6452500C6CAAE154F34D07B5E9F73D0949B126CDB4959E3D56BC09BDFB065FFFC7539F1D130704206592AD2A2F967B0B061EF74C072AF52118F662067F7D6449106B36D208B2567B818657F44E1D121005451D9201EE21DB4385DC6A428498B3E2F177B349CC250F6E02F19FFCDEE353FC61A750F3A6BF8CF4775CA52C98D510A9DC4118132641E9F0E10A4A706C91F772622858B95F94D81714F7060A4FC6AC5831453477AE8C620469902158BCF75D103AA9ADF744F33B5818362B5659FDC3C28B0D01389783219818E96056536D27CC6A001FE7736E6E6052CD224CED39C5247841CB8BC9BD83FF981FD0DC7614F3CA125F76F3EEA46161D806F719EBAFADE2F09814349E4A0C295693DCBCCCC243824D720893A500BB58E2C57A3032A7CCB8C62478C337DC4D610BC67B6E8A019FCB418A9D38723BB72203FE29C4AA19C157994C4931107839E5BF66A277D511787376F76E5B73B1191128491661B3C72C7A47C5AC197DF54B67F2E9296A5103F143588F9B100347D063009F615284D8FCE330B0549018D6CB13FB9B4ECAB870FCFDF12F5AC135F7F8CE1A76189664BE433683D92C78A6F203DBE8592F46AD7DBD6A5C023DD47063DDEF4DAF9D3D5B65876405CF09696FEE34816011B1BC33DE8C083910EAFA0EFD974B8131B7DE1B14D253F336936015A459B81CFC7366C4A4264E09C63F660CA9284A0F1D6A99964DF01B1DF71BF7BD8FC48A66C10082442BC600438AF736396FDFC50C66290A510FD1205CF71322528F33BAEDBAA3DEA409ECF4E46466B9090C7957C3ABA352973FF910467D450F01B35EB017977C95AB491326759213CA30097804C19D4234E2FF337D0B4F2A8557F7ECE4D89A01CFF110F7F5BB2AF532604633FCC78622592E56B61F16E0A996FADA5C08A4B570358B26747096664930AB59C1E4982C193581CA299257AD5941604F54C36A46B1BEDF52CDDE8B00A573D4521C2C3CE11E175B12DFE4BAC609EE1695B439FAF77A41BEA95EB020A8F2A58A3469363D193846A59AC5AAA726BD307BA7E356BB6B6A45E98811A4266FB21E20BCD790D9EEC41A8D5B8D87127C27967DDF2CF026F06ED0CC874654688409C3E0972F4E97E2329851D214139C0B0D9AB4BB79DD08C3EC4D2A2696A8B1BB88C52654AD1E7B2EFC49CD1F422F521D3303117807EA90C2ECCCAAC75190D69B45C9DAAC2E4943300E6FE97801DD230831F8A9F7999B70B96166D1B0370F2A4A1328D2B014BE16AADCF00264F37887981D001F23F6DADDDFF3040CF7CDDD332A19C166D4D2D1EA7AB366BD6531100E03DFA81BF81562228B5C51F7B4FB2645983DF8B506E8732F49E1557F8A18A7C2BF98301AA272767D239AE145C7D2533F10B32F6378EF4D881741E3C23C2C16AC6697DE0F6DFB5F3CC23DF1055D5E93F1D8E9E61E0726C56B69F341FF0C73BD213123D9E2C442BC179BAFF7941F5E7DA15C78036720B517B00D4F6D542C8A5DC208587817FBF3701326D171FF05984D62769C8E5C4D7CA3121154589C53F7D35E84198F19CCC1DCE62630A45E8E53D6550CE3BDB11C42783143838681856A252918D20C79C608D1A4593423470506A3264783F46DBD18E66F0902436ADDF7C369A4E104139A03768A208605EF30B321FF85E5528C4C8822277561E576004B9423BEE6D7D39BCD2082536EFFBB07080231F2027F122240EDD314A67D66DE174C20171BC91BF9A660CD6A5663852BC586C1ACD20820C4C8828B5C0117633659100C661578A2436046BC05BD81F1438C091EBF6B8D89BDBDD93BB0B55AEE2D64C4A2D8248A753A35D76F42CC1E9C4DF7508A5DB4B463F34CF9FC7ECFE7A696B166C4704993BA9BCCCD6605A6746019E2B3E831BE9A1D62D3462A1360A384A3B9C998900911B8129A3D6A56E63514FF62040C280557FF67F7CEE7C3BD107970F7BA052513D60C6058246EE4056976185D9BE0C101A5C206B18BD730DDEC7C53F78EA7C0051370085292C60011AF0E31925BFC32B15965E1C850077D725DC7CFA966C0AC0D104402B3E80500DFC7D1A3626FCAF9C98421E4D88F92E3A9970E66B3801704C43FB92034813FDB200E5D0FE346F5DCABDDB8E5C40B4693A5CD7F4D78C99A86453B2DBAD19162EE3B56F3D463DF81DC973F90F7033F55F79D83498D7AC18A0DD4CDE56A484190629EA49FC14D2E555ACEA91B4AE10561D29DB710DE5EB28A34D1465CDE3CC9CDD3A1C2E9A72A0FE0DC531DD08D95E14EAD4AAE0EEF0DA3B355488B4D8859CC561393AB7044E0178DF77D20C5CC46B1AD1493B158C3A03912C92B36AC59AB93128CC9D42C30A911B700142FC29B31AB3843C1A426CC62DA10F77CCD62C53F685B5A1EF757F1E44D9800CF4C82EE96C6A437C930B032F4F63F56387AF305C06D45BDB0F7E02236810C91E63D048244B0EC4ADDEA958CDE83389207E8A81B4FF734DB27CF2E3366CC629DEAD7764588BD604904E54297B6B7381450431F447ADD2BF1D71A46B378C9D639D061524CB6E144463183823168E20B9F966A745E2A5324D75B2A865BE8241672FAF0CC7D64C1EA4DDF09737C56CF0583A416CF0345071D6AC54FA5C56289B8E2103103955CE94D9A116A80D500C368463030BAD3846644D6C8FDD7DD025B720242E7C741F77487D39326CDA04DE866D98C1846441F13D104FCBD4B60761E7D53A35E2453576EED35292A108B62CDC8FAA95213081251B091426C33180140728A6661F8ED7D1CD4601F50F7E1F382611214AC4092152486410428553B4A6FD20C1EFFE4F1BE318BD9EDBDA03F43A91770CF69568421799BE66911849AC4DA056C14A966C8347EE35865EBBB15F70AC251CB44D990726F4409553966BC17A415415E9A96DBDFFA78165216934F4F2E734A44B97FD5EC10B75914A3D98B8B1911825259C70A9FBD4935075721F3290316350B1D3B4421141747661561A9620BADD526307B110E77503D3F6C08F5654DBE7D70B0756CC6EDC244036B43DC8A1ABB37031287195009FA4BA4593360104C2D3E158F1475F3AB7A63650326E8AABB10045261FC33C0A06015865526B990070E4324282811EFC526545E6914AB0F51180400FF25A0822D5520A498674B9E07C508901138FBDAED7FC204002000808003042001060007CE35F3160680040401021B86C59A730E0A1B2B30B9AD39F72A1D402A01001562CEB9D73A80020F38222874049C00910A04CAA7EA80FC3769B0360BD590005B1748002C55FF8E894DE88155A4327183BEA1FA235E315DEC8D4D904975390145A8BD776BAAE1E90B551B61867BDD7BED986A41BA88201900B9EE39371A9C8D8A20EFBAE7DCECC0189E0DE519800EAFB977C6B30A0C1B7D1ED91E0B80B13C8036339834AA8DAA55757784CB0A783B5C5F9F8DBA7E6EFB9190F03835383606D82AAB66767BEFECF07B3F8304A30E880EEF3D3777C18887533D173BC42283DF1A2A3DF762CF0EA92E48A3A07203E08D4F80ABCC5AAC23CC861C3494228322057C54D533D0AAFF370889D4836DA833F75DA8FFB5BC7691AA9B8F45A050994A853037E134ECBA5C94DE00FFA6F70ECFBD88A80AE8908C8BBDC7848344D62EEFDF7B6E16F1271326B1202FB8D87B5546B96DF5FF75D07F23C0747CA82C38346832343537B07755E760606A0001120C73B97B46FBB8345B33C9E97A17C1874384D8521FF2C87807C37B991444557AF1DE8B4580C1BA118D7788C5880A35BD724944F01E87872D4241F000D0A989E983E1D135FE5900815DD4A4019D1F49E1300360D0DA5FFAA0A375BC38333732FA380508F8823FB9299F819D58814DD8373784B1BB06C3E4C067EC04BF043A84201DDE8CD03E6E47ECBD58032419DBE578B3C3A48274EC12BD18B177A9DD10D558350836F70F838470C410219700FEAD75E46A37DC6D8489E0877BBC314EB83736BD6CB852C02914CC3861F72F04FAF4314DF80175F4B250B1CFCD728717AF44A448DE3BCC2264C36FB203BD779AC527A57ECCD6E13DDF8B0BA44580801A98C50A983582D21E16C0AF7E93B835B438310B47BE0025354E819044A120593F2155E8659408BB5F3E3537318432333635B76C0B115EB11887F32E6F317BAF1931A295CECB1A8CC321D25E6759C1263D82C026B902383C9EE90620E52C077F0AF80A49DCC775803281096F155A14463A095DB86B80ED353250A04921D0FE3762AD9EE52832017DEC8355CC36313823C231185B4D5E01002FF622CC87D9A77AAF638F177BA122A7A7C420DCB0777A150A92CB908AF0DEE9C600BE43B3B8BB25D92A5C9333319A353333B625157C5A5EEF58D3BC015F5F53B50C38FD16DD0C73185A20E6B952381C5E8C2E916B285169C23B4C4838BF3A84D8736FD6D10807E6E063C68BBD0A0FBA20C68057A4172DC3F18815B984C8D8DAADF335C61BF8BE06884D00360A01C2F71C1964F7BD52E952D963A610AC58A79DB24C64FC43B1923083C31F48401C66BCE781AC9BD1FA358CF7269DB9C1E96F1211826D9F06D481C06C7F0F506A388B709964899764679707B4A480779C4F60423734373314566BFAF5318D73197DC784D1540E014B8D3AC390CE7AB326FDBD70FC71D19248F662CC4B02CCD78C482F766887A0844A62B3F75EA610202ABB10DE7B3D5A4DE82433239F476244C2A43134C0389CEC5C0527F49FDA70578D603A93780F98FCF0DC0A7051E1D0323420193C9E7C7F860058B1D39B75AD24BCAAA6EFC51812C55A02DEBDD72C12EEEC80AFC40E41E0F02EAF59023E087E70838D0429010B10371D55EC396040502218A00106418B84516369F1D3B98678ECCAD9D8FF4D94A513626C95C466A581A362BD9D8B31A3BD71B767498BCD70B3CFB5D6B084C466B31783A01EB884494C3A5ADF2B67D969E6DEBF0139AC140E192C82FB3032808814E08C586916DA4D9BCA76A9346035ABA04070ACF73BE1399E11F05753CB683550601CA9DD256ADE68E0A9646AA7318919AF36D1CE6F081D82415022069B8DF44EB5061D00B9332F166BC6768DDEC905B3081615E6072FCA1B80313832774F6F6524824531A78031BDFE7AA17D1611239CD0F79D872955AC46C164129410929250F0B935FF37E147B022EFC353AE2004F9182358EFB904D1C631201DDE8417E3AC9F7E6C48BC19D42C29C94E38CC5CC7CD8A9D009831C9875E60EC24D6B3204E14B429B4F397A482D08709839D2C0ADFAFF4115598BEB78195E637085EBB08DC127D903BBE7CB753623063E69BA547A53BC4E0BD86D85492878CD824DEE5EFD0FC7B4418D67477493C114C98D00006107C207854BC8857F1137F763638FF4E08FF852989759C5B04EDB2E0E4E038CC2F14ABE02B20AB333B464FFAE45001B554B76AB6CE177BC5081A5AC49FF49A0589C6A6626F1611228A61DE2CB386F15E98B05DA86F489D624049307B43C176788BEFA388B6B076BB0D27F8BE680404669C952D0962647CC4241C2036729C423226B90987672A567F244A67747AC9885D09BA98D20C779AAF96B546D8201D9E0B9B3F94A3DE0466B1D8A8343706E3E404D14031AB3242C493AFEE80D4320BF2B521811FF413288CC9FC2870E826568C34ABA42670643177E6C6439B3584D3774AF6B58C19A7C38EB13620313BBD434BDFE4009AF1DE9B33FC3517F989BFD19397015D047DF0816DE4384A6A41B4BA015584203045F06F34B0314DFC894D888D85F822D8DA22505772281138B03347281885D3A47B6C220483088E43CBC39AD0ACCF1C344178BC0305BE0E75BD58C10EFD8B402F52B149EF2322DD34DF9F81F66F7458C0525781AA0C5F09248C82CB1E06A13386D136320ECC882C828F9E0639534AB317895DB385C2E101AA89C36146035CE617468C6634ADD21C4816432A73BD7B6F09F020DF221C224B888835451E15640C4361D65C422EC067F76A3153C2734511D1B850763738C52786458B9609E74762ECCE02D670C25AA1B478B159935C0F83D2E14D88F49C8F671D86663C860D2F2359E1CD28F6D4EF4EF4887A63FBD95A81759832813109EC29BD7A44BC7E6D297DE8ECC8CC8D4BB8201075DC1F4CFF5E929DD9CF40CC595BB5358359EDAA5D451E6F6241C62690718081A48235033F5BB593DE2CC6DE13AD6DCD08487CCE804E4580D6D93828A2F0F20067DBDD59F4578B4B13AD14696606AB7C3308147E419C8D462C3468261C8C6202CB546CDE1E2F0211FE940E231B46EEC50480A1E00A66BD86D55E2E36D890DE01DB2A97A4C4B149BD1FD7426A365B2FE416387997E8321035C816275C38ECA50855B66E1DDC173434E2A4B07B576368334A340145C8B357F34D7A8718B86395DC246245E0119AFFC5AC1933170326115C60F682C582C2EDC0610244A01C7A53C1A3272F568D95CC101FEC027910B520538376071B05BC6275B468BA7076DB59F8DC5253898CE1569C62D6BCD8E11DC77D18970669420C22FAEF3233C5DE61C262351E0C10884D98AE70CF13FADE8C58E3551ADB52234D061F105733CE487888745122C93533898674732403E27DDC02EF7D0561C86A1C105491DEE1CD78710BBD51C3664D22F6A519029CF7829DF51DCD80042606196F02B3BA7558BFEC1656C42089B88F98A6CC20402200ED15BED410243662D4217DEC5F7A0D31A9016201C2F12C0EB377C88E82B1E9150196C487790810A1205DB39D30ACDE21DA31D670E2C58A8306D92279BECD3F7668B27413A347A004A6ACC16FAFE7B2B8B9BC53C7042440783678E0B379532CC0534CE83D3EBC2B42858580C30B022F725CCD884849FC3A23581084193B3A33AB61358B3707CB4DC28B344DC3EB00ADAD881932C635B4C87FE0DBC036073883B5003F117DBC81AD6814FAD92A11580955B4998F372244D31B194DB4A4F188448C458427578458309B8F0A1B51B359BCC3E8B52E85EF451A523DD543A72336A478B60B1B1E499A6F14D6B83736376CDAC8ADDC9035AD64D43394BBB133190DE01D602B1845B6C2343660097C794B0481B6463348BB8C4A340A156ADCB46E763703EFD0732C207893A9601C66D06A89A349B1093035BE5715AC37A36210DA98D40C26F7D06502CD9AF4CEB6D92E8A494B627460F123E20CAD326DAC0116A3E251370115D2F4F3C984C8898D219568A78954F150F109B54C9D806052BB8115CA7954AD6CD67BB319C40702140AD61BC63CCD5936AB58074F45F0B858F17A6F3DB5DA2700B33423735E90018764EC1E7DB5566F9BFA0C98BCF1315DE03983653D6BABA1FC23C06BC3344DCA16AC59CF7790B0AF8D759A412C861100B1172B92C899293886D50C0E74D68270B309E00054E0B9C68025653B99ACF048938183A54340061DB9852362F5AC3475B8BBAC275F001C6C4AE9480F22D08C597AB543DE845833AC41E28CB38A308B233F6A5831A44814201386C59ABDF7C73DFC891C4936C468B951E207DCD28B38CA98815DEC32C26418C0F03070B85BFD8362B0195DE829A783B3FAC15258334C5EDFDFCD6236738BBB085A6C568C5958AFE586A4F76631D4CEC3C9BC20BDD31910ED52C953C4623B150320BCECA0C4349146323789BD24D1006603D5B57439C34373F2559C7034C897A0526DA943ACB8E230AB43EDAF6A0719EDC54E130E342584AECD8A119B7CAB245C108B14EBDA498FB8801BC609EC043B1E3460939A59398AD411858F59950081688E8A0D4C0F47F0B2D8BA2DC165907EF406A8312DEC5E03CDB640BCC22ABF6106EE05A31085015E841993486FD932307BB347A4A1BD9B4C9A119B8912EDA74687E76615554BE8FB01F49BCF9436575C9850506A32B07BF19BD510499C4F9065DA66040366085E62E8F11EC1626112B95187D310AB553CF07A1396B8DAD4F90BCCDE9B4648303231F8B495AF88FE74CC053C5C111B5F8D379F5329123FDBD997A023C06A348DA8A3B607C5501A08800E40A5D6B46FEA5D682D83360126D4BEF158AF8D42EF4D604BC27C743CD1040A220B207CEFF082A1B62A3E008466D4EC33A439DCAA385DB0E8D861D86CFD62B411C28C71C5060462A9C381E4F7B2B42F7804361A839E32094DCE463367A2E9434C768D2B091C600862118FD92C167D819F0A8749417899F1EF926FF6DE7BEA15B4E24754FEFFFFDB83C409F4A2C0C416C0CC0880EC6C306100414A8BDA81EB0958CD2F01FFFB8D278BD48142000A5B5A0F854210DFA18DFE5973DEC35367850AD55328756492DD24E0341F1405A02630333BEDC6E085C6C80058A4DF7E23194C08020FF9384C2256A4E1C9C4E941936617719B7782350B37E7A3272BF686F0DEB9511780FEA4D8388022908A78356838334C26D9D09A8977F774B06574169C3876AD48D79F7B894DACD20909BD785B19137A74BFF881CCC66DDC248C0931667ACF845160D6ACDEB26C58B360064C00ADBF482F98553AF48BC6A45EAC87565EC43AC8F6E9D8567B575FCDE05D6FD142C55B0C540BEF31341B4137FC5976500C686A66B3B17EEE80E62E80970933085213FFA72F3096BD18E4688023114BA8D3BF6150EC4D9A3596B3E9B50F2CB59EB01218755D88871CF5C14FAE8883AD2500E08CA03180AB04BF3DB95486322728FF490A8AC5DA6DF2E0B14AF09C7ABD6010243BF56B61C60C829DEDEC4869368B3580E315BC66F41E3024A99D0E31E9F1533B7DCA38429C27A9583372AC0F5EB2F8CF44DE1A2F2C3D8A44550CCFDCB9F47354A40975FC0334FFEAD3833E6E8083BCB869521E2F583D83F5B6AFBD6114A30074ABD27BC198A1EDE7ACD64624786F0D09570EBD181463FB0CEE09E8812C7310D03476069850237B5AC5800E9E603558F802C1EE8B4E79EEF0B058A1493089629DA42E21024582F1B77A5EB026119E37A6B8592CF6350500DAAC5934A32678D4F8C5201BBD5B767868AD5D015761AB7F7C1DFADE816CF5980155902504F425F6C041B661687C3B3C43BDDC2722D1C03DB47054678C49348CF42D0E06BC49359B9820DE0CDE6C22307AAA26F486F5304148512DF5DE84603B15B7E8B8E2D90E038A086809C288832CF4486A28158CB370E0A0CE8BC4576B0C56D0FF3660B3938241A34F41655205B38A0061BC8725759A0D9B1956E8454812E4FE3ACC08064D1354E538CC28428C924B5CD59DACC5F833B468D8245AC806AB6115F10FD94A40DAD5040A83F1627CD5558C32F274726C56CD98948EAB9F59B39811D2E0E12F0205810D9A93ECC58860DAD02B1BBCD69B40AB192C84AF11C011795F9044048AD4FC214D8421BD6C0157991A58402FC0340BE0B003D867FC4B76792DC58A6113459C0E9098103B32C6DAFF624328D2A1DB97C0CD7A3116B771AFD0A4194D842008EB015C56E958250CF564E9F0D068EB584C7F9CDB35E29044DC351BA46EECA362047B30B65A9BF66604ABBE850DABC570412AB1261E4D78B149F9DE357E9E62C93A5C321A6C1817C43803BE11AF0B9A0728744EC2093DCF28BD6F6AAC03888327310D362975D4824AB54150835C56A4DD12F5B15F83C014E904336820422DAC98AC176F0F20E03ACC3AB1D2EC7BCC2635A446F8E64843680634F8466701BD682F28351A20D255A1DC1CE4A3D41BDC9FCC3268AC3835DD2A4DB2A963D0B9368961A0586736E28C42F0E454C3448C596E63876EB097337AB1207A9385829A456C06DB17929BC50E934E63F5B24202622FC20B50562FA907CCB994E3BC32F1730B0756F38C354DC0014003814E997BCCEAED92AAA34BAF922EEFBDF726179C75B110BC050F8605F60E134C8065075165969B11846C610448D4103A61BD200FEA4930B24F44C0537265630338D86FE8DB3511B51B0B7EA2C25F9C8155D8F0FEBD825A06611D835D90384085783443E8C861352BA8B8FDA7DE6316E1672738AF12D6492F4690EB1B0159B309C480C06D06E1BDF77A306B402A08AE384DAAD93C84A460160EE526B9EA31ECBA6242DCE4C8CB6B67C18F020BAA368CF471084C2C6B60AC34330926B581A6EB646533623366101BA2B6666FC290F4F3999598F186F5A4FA90100CA119139BE3E82D058907AEA05F8C051A2F14D1814594B695042FB005A1376AA832FFDB579638BD9733BA911EA02CBC50863265F4215DC46194A843CF146B23F5161B2260CD0B677D733EDEECCD4817B980CD148488CD9A995D18052326CE59ABC0CDDE2157304003308459431DA63C36D4293885F1B4B031E1F6A976A7155D8CAA88FF5706D41B10B86831352458113E7868BEF2F4B508C59BC18462BC9D6655308ACDFEAD26CD0E29AB04A35C635210ACEE3C497088BD175514347092C96AB3F89469757008465BB2C57930B9F9B2D483C8B4F14E3830908A0E4F491A26F45C07061473B87362C27B339605492836631231C67EAB919124DE61FAEC1A1398CD6663FF38DD11998570F961A4D60B0928C95FEC34E633A033C4366B1D515527232842BFC950D0B1E0C013D0E902B9E01129668C8CC63029DE30AE0E9BF78640EF4CAC3415C22FC2108A1299DDD49BC17B2CCA790FB824A2240928503032D20BE08E35BC7D81F70FE875CC819D741AA5348375C493C5206A395FE63844107027373AB355B05EF0212602C526101126E7802738BC532C5F81DE9F666F56414F20D9D68C4814A464FFEFC8C29BC4F3ECFE7C1135F8E420FF582C29592C708A6554A5BF315B7210359DF089BAA00250E20FC491195DC801298C988B4EA7CE9C85625284587A745C20BC1993710FAA579398CD80091FE8CD78337AD294C9293EE2118B21B23BC82CCE7AC179E431FDC02FE204E5A19FCAD5D6A7A2B84D75E4633822461BC0B058846AF1623398CD6BAE1F6C0D89599C49748A662E368BA09CA89EC2661D923DBE2C7A32C7FF1F8BDD508F028B4424148BC85F81C1A92CB3F706FF6F81E9064FBA6877F23E8D7F2EF26B4008587304FF01FF77018A2424ECA85C058BD884DAE9FC08C28CE0A4FC31C4B07AB36607829B159C1EA0649A3F9C05A1373E144C20C9425B133E5003A09D2C566CF0F8846CF79DC2C9D0D81A26634C20D33C4CA008521F5A32B1482871EFCDDE2443926D82B949CD261467A088C561528F88B07529D261490FE97962D146EE0D0D30F0DCF1425453298318097D84414D3664255894FC33495163A09CBF0047FF7C629D548D55F01975A868378CB019EC226359500A6BC13BBCD883033AA060C00C820DF28FA4189388E68A6D58936AC612525583093C2A0FD0D4CE246D7CF4197D886A98D9741B68F2DCAD3238E4933537814BD62118432489DE06F8FA7686D8516FB07082143B0DD59244106B061D57D60DBCD92C9A8EF515DC49C59B042CE97A5407DE8C2609B93C0DB0B91A4BCA0010DEC8350524D9A01CA4E122BE8B022A65306800F0B67A7FB27572561528554483EC0442219815CFB7789F092B562D61D6862568338A496F1C4842D4902611D186BD60C08B17C28752980D890918B0A11702D48F0E551B27440979823214D8375F515BE908F014559C313376B1DEF79519EFBA81A4C6D609910E57EEEC80792420596FA3DDE01E9162412782E3CDEA0DABC7409120064BE0BA7E987450CA5C7298FE09CB8802D51BE2FA48336A3439BDAB9E1C448483C0BE545A818B7CB6B6A008090514EA001149B318DDB3741A788C370366B876A7849D6611ECBDC97DBB5BC322661C6FE1AA66046F42E6FD7287154120E80CA04EB526142D13D462BCD02302C18C0021D61B67E397B6F800895DB048382104BBB08A277F1760BC4B20D5C138E03275BCA6A4E005815EB2635205A3D8CA99442115B1621CC6B31911AC421A0E137887098C933CAFD1FF06FFEB0241480BC075FABA315883F857740258C330016A528C50C9168416117BC0F8A5CE668038056051A3170B76A983167256E84DA20905CEDC882141EF09B72D332A084D4DA96937AB820084C6238A50C1824A2158C1241B8780790C355090686808319C3B8A420FCAF0C7E898323A558922DF611930A30E56CEC17878BC20BCA25A8FC7CD5E2C761315B8178E62168124823111DE2CE04DD0443631940858C425BF67D0A7964562E49C8175A3048D1038AB18E0374018A02E15AC53158F193CB99483DB60EC3CA9C08B1D669C2B63969B30A909F5295B1CC62348D1E6120CBD861463E1662C00F78604C3A44B35644519E27F84948CC8119187FB4D2A61F7D5A2689E8405239814F1B488C4AC6685F5B430661130D9CF279AF582D4183835339A15C438BAFD2629980450F52CAFDA1C54CC091C8B8BAEDE17CC98BE7235CD58C4217A3381A5AFF0CA058D7521CF687C806D135D1732360452FBEAE966C5E1E0CD240792B04834A14A77AE90825940C68CC2AC59C1041D4C9318362B19BAB706788F7ACF09481AE58E3C9F6CF83280D435074BB4E50C0AC4F1C8A337039CA546455D141D3E4C17F46F1AF77EC80F37A76105932E0725CC9A117B07C2870B13669326644D96666316EB00C3CA2B3DE83BCCDEAEEDAF2F890657ADBEBD016A743119C580F1318165F01E5C5EA559402970CC698783D1A737966497EF8037DE9A106B42FB854B8A149B45CB7DB385269C6633CB0B4F7B10A219C1AEBCC2568498D0FB5D20229F0F206D489C381435AC9650316CD9A02386A9E35341204F8A61D52A857AE262C2135E15615E175C54B8499376D00AE94D8A92C19DA85EF55EAC37A34425B46CF68259D0BCF6D51BBC08941709CD646117982734FF834FF65FB9A8263415535311ACA2C899084C3E4CBAD4786A5024B226B916C65656D33473B15EBB8812861611A120C62DE7101B864B08DAE3521463563DCC4D0252300872FB042B508D40E18C7112F051EEB0E734B5A34D12818314D2FC51C14BF840DF7E3C614D1A9A4D8A2CD304590B3C6605B36715BC20568421FA5D2E6615EF4D7DED3B99250B5284B31320AA3AFD445275CE53F41ACEC2C9075E6D6E08762CA5FA6670C1A0CEF3AB2E509B327ACB63683400204E3A185BEA1C4C162F0247B3826AE9B8DF6812F048A6D928265590B9374913264DD16D779B98F45EA4C5C6E09E8E9804CC4C01883AD6439E3854FC333388314CAAF0A26764FD0B5A32D224442D5A5F4D623811078966981575810E0057ED5E2C8AEC316516FEB72D9BC50CBB2590C5DE2C12ADC0B8D52349318A117084786055B01741000645EBC1C28049B0CE0BC17020B229EC03935D5655E16B342B7C6683088D453D517251C038EFB15F4D7852659A9D4A4C82BD64F05EC694FB126A4230E3990A92464C78C1C48C7EA3CD1E406C2B21296B16838A51D9CB1B7E3CE964C81C9668FE275352F7501FAA5A6833D2941A113F144B50D813326A368B49F4A14D4E5A03642D9B152B366BA6C374300398145494D224221889B66778B13763DE263FE5D30398C51150587D8B4075B67E88BD9279D1136A288F5695FC234B34A4741498A8CF806600B89155D804CD62460D5688050182CB1FB31398D530176CC9768A457816763D03AC6846CD0AD7A43510E04D1FFDC2A928F154F5389D27A23A550B6AC4010A61E53EFC76828F4E21F519E9828BC5A420CD1465661084377B58601A42CC2281CC5130E04D989FB224DE2B48D7D0BE478D005E34507D833AA89140378437D0599089AAE499A34D4592CF78943739E176D41F83FFFC115DC46A316A5C4993A937E3C5628511768809B38635D0DA57C462D0A472FA18A449BC5958CA02700E339AC59C9BABEC6A13357B8A548C3B4C992BD8C990D894063A3D55EA39D429BFA2B868169B5018636E8B600441892ABF4CAA9214D6821B42F06689A033D7308362042B561904BC18D9A56982004B54FDE86FF4237E2AF60D00804C7619D176A3BF015EAE7B00CBC3ED238042611283EA0BDDFE7F1CEC008B00F3043D80020880FF1781B9C839FFEDFFB7DE07BA80370448A604106D0FF474290E48809EDD04D732F0BDFD46FF04DB8058347F84CD7E6E3C81003318CBA1F8FFFFB70BF60D2A34F48041806B66FEDC7B18000C5313003D06D16EFFF646424A043B1CC8801F2100106E80D001FF6FED8D9849BD10657E1873F13B612300CEF8047366A9EEFF517B04B769482480A300B9978C27BF3BDAA0F200E8902E58FB8180967FFBDF2E22604D70C40030F71F04773C0A88049EAB88B8ED5BFBFF6617B08060800350916A89FBDD34BF00B6DC232ED1DDFDBB0839CD4A8E414F0580ABC825049144D41AC4FF42DC71005FFA3E07CC724959B66D5DD4E432CB18DE3755336FDF36C0BBA3DD90D5490F00BBBDE0C49921DEDE0A25AC807F3F200EE4DB6FEADFD46D388080C209A6CE99DC04AF800EB66FBF7D346610ADED3F873FF77B8BF0C2020C836FFFEDA614F510820550EB462604CC0001A9F680F8FF37DCFE49E0006787015124C398783CEC9326C7AD80BD45AB56D4A6DAE504058B1C3E618CFFF0957FFBDF3F501AA72C04B247F9049D72243B000043D0ACFBF6855B99C38D76DAD9805B4D28E6C79511FEC2FF7F707C95235C00EB8073E70FB13C46513DCCC26EA380B90437F5EF16BA8FC52F5400C004718076BCE380181BFEA6FEBFC180CA80782DD85BEBE2044D04840B9ADD04FD0BFF3DD673BE00B7BD039F77CB8BBB0D2793FFFFDBBFCC5A0078C15804A736702CB80607FA008580C63180E88034802B04BFABED54152874F8885D1D0498EEA02EFCFF4BD63D7E707004D9631EE9805361043F9D4A043A2DD1B7AFE07346EE8007238D0E6B752BB82C6CA21A0361897A7FDBB67A304009858115865B0457A7080BB185AE7EF57EAC0BEBE4FFF44438226FFF7F8AC051BE4A6621122DEBE1E556187C4D7EAE0BA3BB6357A2613A00BD54EECD09121B77BF7B1EF7C736727AE40423EA301E724CBC3CEDFFFFFF009E80BCA700ACF1BA4F6007457207889C6480555591142A801C6C22FFFF5FB6AD0270FF52042A716081D8918A4ED67BE304EC974B6CB66F7F036E509258875A55209B0450DD85C1F76FBFFDB7C4A9E904BBA7803B195ED1E977806567F1C41467F6B76FDDBB83827B03DC033080EA6010779BBAF698F807B8F02C80DB2B8534C550CB83DDC0E3237E23122F21F84E6422BFE41B5EF87F81446C96043580258013B00E00C22E1F3F18A57FE10B88D7020D43BCC10A04B1F0DB7337371ABEF1E0D3C940C2E16FF7B99740DA20B4FF7F6BF8763A9846391B1D0361DB886D0D0CB0E791FC12045E163BFEFFF60AC1A94720228016685B22CE80EE779322251470FD00BEFD0BDBE1C89ED9FBFB546E6300279566E04B112216F0BF35EA5A04DFA46F80B8D62388345EFAFD308871D3F23A0B4CF3BDA004D81B0FF1DFD580FAD21600E49DAB5A01B21EFFDFF0FF3302449E2B009D090025376BF22D0300D9E2BF07F927804008C870616B6D237C3071FEDB04A9B7FFB7DF13409DB81D0EBB0733108C1904A2004FBDBDDA3174DF01DF2EC512472FFA551E620509EF6D0B5CBB131C96E12D8E6206F62F15FE1D80872800173C370BA1F104180CE7BB16B77FC3FF8E3211007700BF2ED44B931C0D802724518778045FC697DE6E0E24206F1504784800A924F640FFFF3BE0AB1D8F0500F714554AEBD200B013F998A030FE53F1C358C1DB004A44C62F8C0DA89CFFED8D7FCC30A5B20425163A19C00FDFB02C0CAF219CE180B0F0F6FF6F84734E8077026ED34E00AD81C08032B08D049985BFF577DD984212002ACE00BEC6048204D0EDF92F6D1C0F4FD16E2CE5EE229E1B39A36F6DBFFB026C1CE7C127F022D6555349159EAC1A2600FFB7A5C2327CEA27660EE24F32C9009C9BBCA9307FE9D6FAEE3C793B4675563858CE390B122E9F1E04BFB5B71D0800B1FD69E893025004AA6BE3B6DDF44304170F0265F8CDC1A48B7DFB127082800BAF95727005C26D58F7862578BB179C660339F25966D444C23770E3D16D103201191B3DA6601AB8DE7FE31BB61718FC474B18E93EEF9D0680E0F693FF6FB8FF3100B2200451C97D601BFC80430006F0D961E1ECD81E7F7BE9C23A78790EBE67911617400BFF2D1CA81AB46DFBFF0036434680C5AEA0160F60F468FD9510E21AC1A56F6FDF2406D30C044000AE9A0E0E6E2F2D35FEFB1285C146EE440A9729B75DF1DF0F18A2FC7C9923A20D215B0B31FAC76FEFFEC661AC96528009EBF6192D67D8000269652A3083DB7F6B5CB8F9FDA09EF083796E8BC105724263ABF5C8A0ED3C841718D07E77FBBA7B77C551C2F96136BEA86C00D0221BD8BEA3DD58D904F7002F299D0B8B1F7E83BBD62E21F6E29C70A41D6800FC824DB0C0DF223D2EFE6B80F7B81AD50B346D6C25460CF168583F72ED8ED36F4446CEDB046D8AFD6A58420605B65BFFEABA04627D200AA12316714C6D22C6BF108E97F5C3B5008808C4F4667D236EB0FB27BA0376C422C8F4A3B130BFFD1BF80C93513E40E500948E941760066FA0288710E10D071B46697EA4C7F520FB3F02357E1E7D76CD04CD17980210028BFBB6B5FDACC9C63EC1E1202B88554CBC0380C92438F26F70301F58723BA6A980494B6D1EC20DBEED6174CCB4DC803C8D526C9A67F07683B7FA16018C275C6A2036888096B8BDB1D52B6B1B9F043DEFB88DCE5AFF5FD8129DE440610600407E19E7A0CD423E25C4D2A1DD840320C244D69FF648B4BD0504CD4C38F008BA3098F83F46708143046EDF1544D730694BBF81C66FF539816F20DC00DFCC7B2ED7F4372E04E621480074EAECB2E8F427EDCEF45D41F0D7D03869F17E462EE35012ADEBDFF4045DB56941E80107003ABBCC8610161AF6AD12FF675E109902805AAFAA658F66BEA71FBAB7DBF661AE27703A561087222342E185810BDC5AD80CF517CF602D753C01862FB86F34408548878D38021CA9D02D3C06D1FA7466056786897192F7AEF16FDD2E2C3E27739E0F172AB5FA0172BBBAFD02DB4DB155770113F7C820E4BF24BF177EC72F05883ED8065E084DDD9FD53D50FAAFAEF0AED6DBB38924763DB6A5D919F0B96CDBE2DFB8166C620C16841FA0A0BC049D7B4DB6B76E7F44806756C17462720610B1EBF2AF9BDBDB812F3E604B0094805C8941A6860D6E02A9B5194FA2C04CA5F8EDFFFD5D0C8CCF04B802F5BDB26104EF047AA825638B7FF7D1C1DCA18F72B5F380D534658BC7B2F7F4172885BD234E3A31DA21760397B6D613EDA9B3D784AD2912D655E876FBB7A5B73C2D44EA8C372EDCC1F6870743647F74A480A632703E6EFCE2251B1BC3DDD3195528340C02B76E25F00AC8DEF9F8D4766EDBDBFFC20D1A98C79FFDBDD512CE468F3E22245306F8BFBDDD030C747E857B4D33530039AC1CC93E1E21EAFFD28B6E64E160565E856DA0D02E0287296C6FDB42753B15DA25A4F000CE616CB736365A83907C630C1180B81E34D1DF0ECE173A3833B0206A167EDB6FB45BF49F4D23792151007A0F1D388B7AEB17FE0C50ED51E628711AC4AD5268A098BAD14ADF6834C026911737D42F406E81BFB94531D0C00D3E09B7DC09518E9768FFD0042EC149D9E80509B7FC442B805289BFF45900754D38B429DE562E5B3BF3BA71A1FF3D2A688086EB39A26A43078447CAD0FEB70E2A5A39C27343630980A0010C32854BB72FB68AC6B97C17CA0D9AB0A3A6B6E16D89AF67922326AD01643714737DE942DB8F021A6B9B472B60C380F26F7F630760DE3FACB69F223CE243C8B810DB42856EF170C7EB819F3589C0F36BAD1BEDE62E12893EA4554C7BDEA2F05B5CF9062ADE50DD1E0721F4746BCB050504E6926FD5007336FAAD6FBE6BFDE1B77939800A1C0A92E87403B785CA4A594515DEEEAA4AEA5D89D69E3932CC6B1C081DF3EE0F0C6C0DE44A8FED8675A9156FB7B8FDCD34042C6EE25E06FC8FBF1E0FA9313A8BF68E1B541412E20223DC90D0346CBF6D71044F63C8EB449B8062C9309665816F0D9AF5020C3146B2264FDBD2EEFF57CF98DFBB8CD7F0C910E0554F782BE4314D6FBCF016E30652A2B141C7C0ED76D1A7D46F8EA6E19989F0FF46D43E9BF9DE6E0B3790776704448E100A8008C01D2FA1251A3BCCF99FD5DB2882B5FE5DADBE29382F7FD2FB46243DE53BD6BA7DBB1C9A771F5218474F056430B0530BADA6FE3F7ACDC7DA400F814EF48DD4ED774F7B15549FC183A36DF1DA80A276A15BA1B393C680AC1BFD934D7E61BBF1D89A2C6E70A0201A8EE1788DD233E91DBC3923770D99211672CAE06D19B7B6567B10E885FFA9489C2900B885BFB56F587E20D9CB3E5AF76ECF8082C481E16B04E87A80121BD838E6112A6C0D7C36749FE8D6E402C149D0C646EF75D4AA20CEC7B37971D4DB0D6E33F392F0465BB57EE02C22E85AC94DD3E7A1ABB75B95DB263E413D9BEE03A55DDA5BDDB69F0B3C180D656B0EC802257D53DBAD4140798F5090ECFECE4CB507FF881425EB33C7FD47942D9A5AB79DD0DF1DF5908074A361E3E04665D529718F830E592D03B75A5FD770804892FDF6C65B063EE580CD09A2DD40EB065F5275FA4B4B5B2248D4470D73C71806EA52F4164B356ADC48BA0E4607DD6EFA6FCD046B0349DDB4B3BD430BEA504B066414FE175AF8AAD11A5A8DC27F020383CD2D5DC240FED6FF214D4C7A89772DBFBC63016E133AE198452FEA2FB16DAD18C9D0661DEAF8BF30675FBEDD5A18CF21D6900124514E0B3161FBAD95B0A522248337667510833BC36DFB6D9BAA5B74DA80A7BDBD686D600F5BA8D56062780C436DA526F812AE6D432ABF9B5D8971A8505AD4DAE60F31FA206D93ABB06DDD031CE175EC110DA127215A60AB1C9881F4CF11B3D4C26DF55F7D58F30A78BD045AAB44E8E1B62884BFC1167F46008304C5BBE263271CE9F1E10EC08697F8ADC6BE58FF270106DE82AB572C75A9B017212A97E40120C9BFC437686F1F100677A33BDFA87DB13785DEFE4B6283F1E041D42E5E216B72806B4EC85158FADE7238514B520FD32FB9666A5D30B0C33E1835EC68F1166D4937627FCDDD5EF0BF4DED7EC3D58A4AFE7FD9A038F9EE87BFC5762BEEA6E56AB9E72936040E2C2','2018-10-11
03:04:32',0,'web',NULL),(24817666,'161f138d-b5a0-4d14-8cdd-a81800fda190','$(function(){$(\"#con_llcs\").html(\"浏览：52次\")});$(function(){$(\"#hidRequireLogin\").val(\"0\");$(\"#Content\").html(\"此篇文书不存在!\");});$(function(){});','2018-10-11
03:04:32',0,'web',NULL),(24817667,'37b6306f-8d93-4d30-af7f-a7db010b1113','$(function(){$(\"#con_llcs\").html(\"浏览：101次\")});$(function(){var
caseinfo=JSON.stringify({\"文书ID\":\"37b6306f-8d93-4d30-af7f-a7db010b1113\",\"案件名称\":\"上海浦东有申汽配有限公司与上海芳蕴机械设备有限公司房屋租赁合同纠纷一审民事判决书\",\"案号\":\"（2017）沪0115民初29725号\",\"审判程序\":\"一审\",\"上传日期\":\"\\\/Date(1505750400000)\\\/\",\"案件类型\":\"2\",\"补正文书\":\"2\",\"法院名称\":\"上海市浦东新区人民法院\",\"法院ID\":\"912\",\"法院省份\":\"上海\",\"法院地市\":\"上海市第一中级人民法院\",\"法院区县\":\"浦东新区\",\"法院区域\":\"\",\"文书类型\":null,\"文书全文类型\":\"1\",\"裁判日期\":null,\"结案方式\":null,\"效力层级\":null,\"不公开理由\":\"\",\"DocContent\":\"\",\"文本首部段落原文\":\"\",\"诉讼参与人信息部分原文\":\"\",\"诉讼记录段原文\":\"原告上海浦东有申汽配有限公司与被告上海芳蕴机械设备有限公司房屋租赁合同纠纷一案，本院于2017年4月17日立案后，依法适用简易程序，于2017年6月7日公开开庭进行了审理。原告上海浦东有申汽配有限公司的法定代表人孙祥卿，被告上海芳蕴机械设备有限公司的委托诉讼代理人陈亮到庭参加诉讼。本案现已审理终结\",\"案件基本情况段原文\":\"\",\"裁判要旨段原文\":\"\",\"判决结果段原文\":\"\",\"附加原文\":\"\",\"文本尾部原文\":\"\"});$(document).attr(\"title\",\"上海浦东有申汽配有限公司与上海芳蕴机械设备有限公司房屋租赁合同纠纷一审民事判决书\");$(\"#tdSource\").html(\"上海浦东有申汽配有限公司与上海芳蕴机械设备有限公司房屋租赁合同纠纷一审民事判决书
（2017）沪0115民初29725号\");$(\"#hidDocID\").val(\"37b6306f-8d93-4d30-af7f-a7db010b1113\");$(\"#hidCaseName\").val(\"上海浦东有申汽配有限公司与上海芳蕴机械设备有限公司房屋租赁合同纠纷一审民事判决书\");$(\"#hidCaseNumber\").val(\"（2017）沪0115民初29725号\");$(\"#hidCaseInfo\").val(caseinfo);$(\"#hidCourt\").val(\"上海市浦东新区人民法院\");$(\"#hidCaseType\").val(\"2\");$(\"#HidCourtID\").val(\"912\");$(\"#hidRequireLogin\").val(\"0\");});$(function(){var
dirData = {Elements: [\"RelateInfo\", \"LegalBase\"],RelateInfo: [{ name:
\"审理法院\", key: \"court\", value: \"上海市浦东新区人民法院\" },{ name: \"案件类型\", key:
\"caseType\", value: \"民事案件\" },{ name: \"案由\", key: \"reason\", value:
\"房屋租赁合同纠纷\" },{ name: \"审理程序\", key: \"trialRound\", value: \"一审\" },{ name:
\"裁判日期\", key: \"trialDate\", value: \"2017-07-10\" },{ name: \"当事人\", key:
\"appellor\", value: \"上海浦东有申汽配有限公司,上海芳蕴机械设备有限公司\" }],LegalBase:
[{法规名称:\'《中华人民共和国合同法》\',Items:[{法条名称:\'第五十二条\',法条内容:\' 第五十二条 有下列情形之一的，合同无效：
（一）一方以欺诈、胁迫的手段订立合同，损害国家利益；
（二）恶意串通，损害国家、集体或者第三人利益；
（三）以合法形式掩盖非法目的；
（四）损害社会公共利益；
（五）违反法律、行政法规的强制性规定。
\'},{法条名称:\'第五十八条\',法条内容:\' 第五十八条
合同无效或者被撤销后，因该合同取得的财产，应当予以返还；不能返还或者没有必要返还的，应当折价补偿。有过错的一方应当赔偿对方因此所受到的损失，双方都有过错的，应当各自承担相应的责任。
\'}]},{法规名称:\'《最高人民法院关于审理城镇房屋租赁合同纠纷案件具体应用法律若干问题的解释》\',Items:[{法条名称:\'第二条\',法条内容:\'
第二条
出租人就未取得建设工程规划许可证或者未按照建设工程规划许可证的规定建设的房屋，与承租人订立的租赁合同无效。但在一审法庭辩论终结前取得建设工程规划许可证或者经主管部门批准建设的，人民法院应当认定有效。
\'},{法条名称:\'第五条第一款\',法条内容:\'
第五条 房屋租赁合同无效，当事人请求参照合同约定的租金标准支付房屋占有使用费的，人民法院一般应予支持。
当事人请求赔偿因合同无效受到的损失，人民法院依照合同法的有关规定和本司法解释第九条、第十三条、第十四条的规定处理。
\'}]}]};if
($(\"#divTool_Summary\").length > 0) {$(\"#divTool_Summary\").ContentSummary({
data: dirData });}});$(function() {\r\n var jsonHtmlData =
\"{\\\\\"Title\\\\\":\\\\\"上海浦东有申汽配有限公司与上海芳蕴机械设备有限公司房屋租赁合同纠纷一审民事判决书\\\\\",\\\\\"PubDate\\\\\":\\\\\"2017-09-19\\\\\",\\\\\