reglab/housing_qa huggingface dataset:
NV Rev Stat § 108.2425 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2425 - Exception to sufficiency of surety or surety bond; order to require additional security or change, substitute or add securities or for other relief; court may order principal to obtain additional security or to change or substitute securities if amount of surety bond insufficient; surety to remain liable on surety bond regardless of payment of premium.

  1. The lien claimant may, within 15 days after the service of a copy of the surety bond pursuant to subsection 4 of NRS 108.2415, file a motion with the clerk of the court in a pending action, or if no action has been commenced, file a petition with the court, excepting to the sufficiency of the surety or the surety bond, and shall, at the same time and together with that motion or petition, file an affidavit setting forth the grounds and basis of the exceptions to the surety or the surety bond, and shall serve a copy of the motion or petition and a copy of the affidavit upon the principal at the address set forth in the surety bond within 5 business days after the date of filing. A hearing must be had upon the justification of the surety or the surety bond not less than 10 days and not more than 20 days after the filing of the motion or petition. If the court determines that the surety or surety bond is insufficient, the lien claimant’s lien will remain against the property or the court may allow the substitution of a sufficient surety and surety bond.  2. If, at any time after the recording of a surety bond pursuant to NRS 108.2415, the surety becomes unauthorized to transact surety business in this State pursuant to NRS 679A.030 or is dropped from the United States Department of the Treasury’s Listing of Approved Sureties or there exists any other good cause, a lien claimant or other person having an interest in the surety bond may apply to the district court in a pending action, or commence an action if none is pending, for an order to require the principal to provide additional security or to change, substitute or add securities, or to enforce or change any other matter affecting the security provided by the surety bond.  3. If a court finds that the amount of a surety bond recorded pursuant to NRS 108.2415 is insufficient to pay the total amount that may be awarded by the court pursuant to NRS 108.237, the court shall order the principal to obtain additional security or to change or substitute securities so that the amount of the security provided is 1.5 times the total amount that may be awarded.  4. Any surety that records or consents to the recording of a surety bond pursuant to NRS 108.2415 will remain fully liable to any lien claimant for up to the penal sum of the surety bond regardless of the payment or nonpayment of any surety bond premium.  (Added to NRS by 1981, 31; A 2003, 2614; 2005, 1911)
NV Rev Stat § 108.243 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.243 - Assignment of lien.

  1. Any lien may be assigned in the same manner as any other chose in action after it has been perfected by recording.  2. An assignment of a lien before recording will not be effective until written notice of the assignment has been given to the owner by the assignee. The notice will be sufficient if delivered in person or mailed by certified mail to the owner. After such notice, the assignee may perfect the lien in the assignee’s own name.  3. One or more lien claimants of any class may assign their notices of lien by written assignment, signed by each assignor, to any other person or lien claimant of any class, and the assignee may commence and prosecute the action upon all of the notices of lien in the assignee’s own name or in the name of the original lien claimant.  4. In the event that a claim for which a lien may be filed is assigned before it is perfected, such assignment does not discharge or defeat the right to perfect the lien, if the lien is reassigned to the lien claimant, and thereafter the lien is timely perfected.  (Added to NRS by 1965, 1168; A 1969, 729; 2003, 2614; 2005, 1912)
NV Rev Stat § 108.2433 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2433 - Discharge of notice of lien: Marginal entries; discharge or release must be recorded if notice of lien recorded by photographic process; presentation by lien claimant or lien claimant’s personal representative or assignee.

  1. Except as otherwise provided in subsection 2, a notice of lien upon the property provided for in NRS 108.221 to 108.246, inclusive, may be discharged by an entry on the margin of the record thereof, signed by the lien claimant or the lien claimant’s personal representative or assignee in the presence of the recorder or the recorder’s deputy, acknowledging the satisfaction of or value received for the notice of lien and the debt secured thereby. The recorder or the deputy shall subscribe the entry as witness. The entry has the same effect as a discharge or release of the notice of lien acknowledged and recorded as provided by law. The recorder shall properly index each marginal discharge.  2. If the notice of lien has been recorded by a microfilm or other photographic process, a marginal release may not be used and an acknowledged discharge or release of the notice of lien must be recorded.  3. If the recorder or the recorder’s deputy is presented with a certificate executed by the lien claimant or the lien claimant’s personal representative or assignee, specifying that the notice of lien has been paid or otherwise satisfied or discharged, the recorder or the deputy shall discharge the notice of lien upon the record.  (Added to NRS by 1991, 1104; A 2003, 2615)
NV Rev Stat § 108.2437 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2437 - Discharge of notice of lien: Recording by lien claimant; form; liability for failure to record.

  1. As soon as practicable, but not later than 10 days after a notice of lien upon the property pursuant to NRS 108.221 to 108.246, inclusive, is fully satisfied or discharged, the lien claimant shall cause to be recorded a discharge or release of the notice of lien in substantially the following form: Assessor’s Parcel Numbers DISCHARGE OR RELEASE OF NOTICE OF LIEN NOTICE IS HEREBY GIVEN THAT:  The undersigned did, on the ....... day of the month of ....... of the year ......., record in Book ............, as Document No. ............, in the office of the county recorder of ............. County, Nevada, its Notice of Lien, or has otherwise given notice of his or her intention to hold a lien upon the following described property or improvements, owned or purportedly owned by ..............., located in the County of ............, State of Nevada, to wit: (Legal Description or Address of the Property or Improvements)  NOW, THEREFORE, for valuable consideration the undersigned does release, satisfy and discharge this notice of lien on the property or improvements described above by reason of this Notice of Lien.  (Signature of Lien Claimant)  2. If the lien claimant fails to comply with the provisions of subsection 1, the lien claimant is liable in a civil action to the owner of the property, his or her heirs or assigns for any actual damages caused by the lien claimant’s failure to comply with those provisions or $100, whichever is greater, and for a reasonable attorney’s fee and the costs of bringing the action.  (Added to NRS by 1991, 1104; A 1995, 1509; 2001, 30; 2003, 2615)
NV Rev Stat § 108.244 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.244 - Limitation on filing complaint for foreclosure of notice of lien.

A lien claimant or assignee of a lien claimant or claimants may not file a complaint for foreclosure of a notice of lien or the assigned notice of lien or notices of lien until 30 days have expired immediately following the recording of a notice of lien or following the recording of the assigned notice of lien or the last of the assigned notices of liens. This provision does not apply to or prohibit the filing of any statement of fact constituting a lien or statements of fact constituting a lien:  1. In an action already filed for foreclosure of a notice of lien; or  2. In order to comply with the provisions of NRS 108.239.  (Added to NRS by 1965, 1169; A 2003, 2616; 2005, 1912)
NV Rev Stat § 108.245 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.245 - Notice of right to lien: Form; service; effect.

  1. Except as otherwise provided in subsection 5, every lien claimant, other than one who performs only labor or is a potential claimant under NRS 608.150, who claims the benefit of NRS 108.221 to 108.246, inclusive, shall, at any time after the first delivery of material or performance of work or services under a contract, deliver in person or by certified mail to the owner of the property a notice of right to lien in substantially the following form: NOTICE OF RIGHT TO LIEN To: ...................................................   (Owner’s name and address)  The undersigned notifies you that he or she has supplied materials or equipment or performed work or services as follows:  ............................................................................................................................  (General description of materials, equipment, work or services) for improvement of property identified as (property description or street address) under contract with (general contractor or subcontractor). This is not a notice that the undersigned has not been or does not expect to be paid, but a notice required by law that the undersigned may, at a future date, record a notice of lien as provided by law against the property if the undersigned is not paid.  (Claimant) A subcontractor or equipment or material supplier who gives such a notice must also deliver in person or send by certified mail a copy of the notice to the prime contractor for information only. The failure by a subcontractor to deliver the notice to the prime contractor is a ground for disciplinary proceedings against the subcontractor under chapter 624 of NRS but does not invalidate the notice to the owner.  2. Such a notice does not constitute a lien or give actual or constructive notice of a lien for any purpose.  3. No lien for materials or equipment furnished or for work or services performed, except labor, may be perfected or enforced pursuant to NRS 108.221 to 108.246, inclusive, unless the notice has been given.  4. The notice need not be verified, sworn to or acknowledged.  5. A prime contractor or other person who contracts directly with an owner or sells materials directly to an owner is not required to give notice pursuant to this section.  6. A lien claimant who is required by this section to give a notice of right to lien to an owner and who gives such a notice has a right to lien for materials or equipment furnished or for work or services performed in the 31 days before the date the notice of right to lien is given and for the materials or equipment furnished or for work or services performed anytime thereafter until the completion of the work of improvement.  (Added to NRS by 1965, 1169; A 1967, 1104; 1969, 730; 1979, 1091; 1997, 2695; 2003, 2616; 2005, 1912; 2015, 1932; 2017, 1210)
NV Rev Stat § 108.2453 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2453 - Waiver or modification of right, obligation or liability set forth in NRS 108.221 to 108.246, inclusive, prohibited; certain conditions, stipulations or provisions of contract for improvement of property or construction, alteration or repair of work of improvement void and unenforceable.

  1. Except as otherwise provided in NRS 108.221 to 108.246, inclusive, a person may not waive or modify a right, obligation or liability set forth in the provisions of NRS 108.221 to 108.246, inclusive.  2. A condition, stipulation or provision in a contract or other agreement for the improvement of property or for the construction, alteration or repair of a work of improvement in this State that attempts to do any of the following is contrary to public policy and is void and unenforceable:  (a) Require a lien claimant to waive rights provided by law to lien claimants or to limit the rights provided to lien claimants, other than as expressly provided in NRS 108.221 to 108.246, inclusive;  (b) Relieve a person of an obligation or liability imposed by the provisions of NRS 108.221 to 108.246, inclusive;  (c) Make the contract or other agreement subject to the laws of a state other than this State;  (d) Require any litigation, arbitration or other process for dispute resolution on disputes arising out of the contract or other agreement to occur in a state other than this State; or  (e) Require a prime contractor or subcontractor to waive, release or extinguish a claim or right that the prime contractor or subcontractor may otherwise possess or acquire for delay, acceleration, disruption or impact damages or an extension of time for delays incurred, for any delay, acceleration, disruption or impact event which was unreasonable under the circumstances, not within the contemplation of the parties at the time the contract was entered into, or for which the prime contractor or subcontractor is not responsible.  (Added to NRS by 2003, 2590; A 2005, 1913)
NV Rev Stat § 108.246 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.246 - Prime contractor to advise owner of content of NRS 108.245; copy to be provided to each subcontractor; failure to comply with requirements constitutes ground for disciplinary action against prime contractor.

  1. Each prime contractor shall, before execution of a contract for construction, inform the owner with whom the prime contractor intends to contract of the provisions of NRS 108.245 in substantially the following form: To:............................................................   (Owner’s name and address)  The provisions of NRS 108.245, a part of the mechanics’ and materialmen’s lien law of the State of Nevada, require, for your information and protection from hidden liens, that each person or other legal entity who supplies materials to or performs work on a construction project, other than one who performs only labor, deliver to the owner a notice of the materials and equipment supplied or the work performed. You may receive these notices in connection with the construction project which you propose to undertake.  2. Each prime contractor shall deliver a copy of the information required by subsection 1 to each subcontractor who participates in the construction project.  3. The failure of a prime contractor to inform pursuant to this section owners and subcontractors with whom the prime contractor contracts is a ground for disciplinary proceedings under chapter 624 of NRS.  (Added to NRS by 1971, 881; A 1997, 2696; 2003, 2617)
NV Rev Stat § 108.249 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.249 - Lien on mill, manufactory or hoisting works.

  1. All foundrymen, boilermakers and all persons performing labor, or furnishing machinery, boilers, castings or other materials for the construction, repairing or carrying on of any mill, manufactory or hoisting works, shall have a lien on such mill, manufactory or hoisting works for such work or labor done, or such machinery, boiler, castings or other material furnished by each, respectively.  2. All the provisions of NRS 108.221 to 108.246, inclusive, as determined by the date of performance, respecting the mode of recording, securing and enforcing the liens of contractors, subcontractors, journeymen, laborers and others shall be applicable to the provisions of this section.  3. The word "superstructure," wherever it occurs in NRS 108.221 to 108.246, inclusive, shall be applicable to the provisions of this section.  [19:64:1875; BH § 3826; C § 3899; RL § 2231; NCL § 3753] — (NRS A 1965, 1169; 1969, 823) — (Substituted in revision for NRS 108.240)
NV Rev Stat § 108.250 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.250 - Extinguishment of lien on real property created by levy of attachment.

The lien upon real property heretofore or hereafter created by the levy of a writ of attachment shall, unless otherwise released and discharged of record, at the expiration of 10 years from the time of such levy terminate and be conclusively presumed to have been regularly released and discharged.  [1:37:1917; 1919 RL p. 3352; NCL § 9409]
NV Rev Stat § 108.260 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.260 - Expiration of effective notice of pendency of action.

Notice of the pendency of any action shall not constitute notice or be of any force or effect after the expiration of 10 years from the time of the filing of the notice.  [3:37:1917; 1919 RL p. 3352; NCL § 9411]
NV Rev Stat § 108.265 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.265 - Definitions.

As used in NRS 108.265 to 108.367, inclusive, unless the context otherwise requires, the words and terms defined in NRS 108.266 to 108.26795, inclusive, have the meanings ascribed to them in those sections.  (Added to NRS by 1991, 1716; A 1993, 2037; 2005, 1246)
NV Rev Stat § 108.266 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.266 - "Landlord" defined.

Landlord means the owner or lessor of:  1. A mobile home lot;  2. A mobile home park;  3. A recreational vehicle park; or  4. Land which is not located within a mobile home park, but which is rented or held out for rent to accommodate a mobile home or a manufactured home.  (Added to NRS by 1991, 1716; A 1993, 2037)
NV Rev Stat § 108.267 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.267 - "Legal owner" defined.

Legal owner means the person in whom the ownership or title of the property is vested or who has a legal right to possession of the property.  (Added to NRS by 1961, 483; A 1969, 1508; 1973, 449; 1983, 1037; 1985, 506; 1991, 1717)
NV Rev Stat § 108.2671 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2671 - "Manufactured home" defined.

Manufactured home has the meaning ascribed to it in NRS 489.113.  (Added to NRS by 1991, 1716)
NV Rev Stat § 108.2673 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2673 - "Mobile home" defined.

Mobile home has the meaning ascribed to it in NRS 489.120.  (Added to NRS by 1991, 1716)
NV Rev Stat § 108.2675 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2675 - "Mobile home lot" defined.

Mobile home lot has the meaning ascribed to "manufactured home lot" in NRS 118B.016.  (Added to NRS by 1991, 1716; A 2001, 1189)
NV Rev Stat § 108.2677 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2677 - "Mobile home park" defined.

Mobile home park has the meaning ascribed to "manufactured home park" in NRS 118B.017.  (Added to NRS by 1991, 1716; A 2001, 1189)
NV Rev Stat § 108.26775 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.26775 - "Recreational vehicle" defined.

Recreational vehicle has the meaning ascribed to it in NRS 482.101.  (Added to NRS by 1993, 2037)
NV Rev Stat § 108.2678 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2678 - "Recreational vehicle park" defined.

Recreational vehicle park means a campground or other facility, any portion of which is rented or held out for rent to accommodate recreational vehicles.  (Added to NRS by 1993, 2037)
NV Rev Stat § 108.2679 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.2679 - "Registered owner" defined.

Registered owner means:  1. A person whose name appears in the files of the Housing Division of the Department of Business and Industry as the person to whom the mobile home or manufactured home is registered, but does not include:  (a) A creditor who holds title to the mobile home or manufactured home; or  (b) The owner or holder of a lien encumbering the mobile home or manufactured home.  2. A person whose name appears in the files of the Department of Motor Vehicles as the person to whom the vehicle is registered.  (Added to NRS by 1991, 1716; A 1993, 1505, 2037; 1995, 669; 1999, 3589; 2001, 2562; 2017, 3603)
NV Rev Stat § 108.26795 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.26795 - "Trailer" defined.

Trailer means every vehicle defined in NRS 482.110, 482.125, 482.127 and 482.134.  (Added to NRS by 1993, 2037)
NV Rev Stat § 108.26797 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.26797 - Department of Motor Vehicles: Adoption of regulations to ensure compliance with laws relating to processing of liens.

The Department of Motor Vehicles may adopt such regulations as it deems necessary to ensure compliance with all applicable laws relating to the processing of liens for storing, maintaining, keeping or repairing vehicles required to be registered with the Department pursuant to chapter 482 of NRS.  (Added to NRS by 2005, 1246)
NV Rev Stat § 108.268 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.268 - Legal owner of aircraft.

For the purposes of this chapter, the person named in the federal aircraft registration certificate shall be deemed a legal owner of any aircraft.  (Added to NRS by 1983, 1038)
NV Rev Stat § 108.272 (2021)
2021 Nevada Revised Statutes|Chapter 108 - Statutory Liens|NRS 108.272 - Notice.

  1. Except as otherwise provided in subsection 2 and NRS 108.2723, the notice of a lien must be given by delivery in person or by registered or certified letter addressed to the last known place of business or abode of:  (a) The legal owner and registered owner of the property.  (b) Each person who holds a security interest in the property.  (c) If the lien is on a mobile home or manufactured home, each person who is listed in the records of the Housing Division of the Department of Business and Industry as holding an ownership or other interest in the home.  If no address is known, the notice must be addressed to that person at the place where the lien claimant has his or her place of business.  2. Any person who claims a lien on aircraft, aircraft equipment or parts shall:  (a) Within 120 days after the person furnishes supplies or services; or  (b) Within 7 days after the person receives an order to release the property,  whichever time is less, serve the legal owner by mailing a copy of the notice of the lien to the owner’s last known address, or if no address is known, by leaving a copy with the clerk of the court in the county where the notice is filed.  3. Except as otherwise provided in NRS 108.2723, the notice must contain:  (a) An itemized statement of the claim, showing the sum due at the time of the notice and the date when it became due.  (b) A brief description of the motor vehicle, airplane, motorcycle, motor or airplane equipment, trailer, recreational vehicle, mobile home or manufactured home against which the lien exists.  (c) A demand that the amount of the claim as stated in the notice, and of any further claim as may accrue, must be paid on or before a day mentioned.  (d) A statement that unless the claim is paid within the time specified the motor vehicle, aircraft, motorcycle, motor or aircraft equipment, trailer, recreational vehicle, mobile home or manufactured home will be advertised for sale, and sold by auction at a specified time and place.  4. The lienholder shall determine a day for the purposes of the demand in paragraph (c) of subsection 3. The day mentioned must be:  (a) Not less than 10 days after the delivery of the notice if it is personally delivered; or  (b) Not less than 10 days after the time when the notice should reach its destination, according to the due course of post, if the notice is sent by mail.  (Added to NRS by 1983, 1037; A 1985, 237; 1991, 1718; 1993, 235, 2038, 2042; 1995, 669; 2015, 1517; 2017, 3603)