reglab/housing_qa huggingface dataset:
NV Rev Stat § 11.2055 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.2055 - Actions for damages for injury or wrongful death caused by deficiency in construction of improvements to real property: Determination of date of substantial completion of improvement to real property.

  1. Except as otherwise provided in subsection 2, for the purposes of this section and NRS 11.202, the date of substantial completion of an improvement to real property shall be deemed to be the date on which:  (a) The final building inspection of the improvement is conducted;  (b) A notice of completion is issued for the improvement; or  (c) A certificate of occupancy is issued for the improvement,  whichever occurs later.  2. If none of the events described in subsection 1 occurs, the date of substantial completion of an improvement to real property must be determined by the rules of the common law.  (Added to NRS by 1999, 1444; A 2015, 17)
NV Rev Stat § 11.207 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.207 - Malpractice actions against attorneys and veterinarians.

  1. An action against an attorney or veterinarian to recover damages for malpractice, whether based on a breach of duty or contract, must be commenced within 4 years after the plaintiff sustains damage or within 2 years after the plaintiff discovers or through the use of reasonable diligence should have discovered the material facts which constitute the cause of action, whichever occurs earlier.  2. This time limitation is tolled for any period during which the attorney or veterinarian conceals any act, error or omission upon which the action is founded and which is known or through the use of reasonable diligence should have been known to the attorney or veterinarian.  (Added to NRS by 1981, 1023; A 1997, 478)
NV Rev Stat § 11.2075 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.2075 - Malpractice actions against accountants.

  1. An action against an accountant or accounting firm to recover damages for malpractice must be commenced within:  (a) Two years after the date on which the alleged act, error or omission is discovered or should have been discovered through the use of reasonable diligence;  (b) Four years after completion of performance of the service for which the action is brought; or  (c) Four years after the date of the initial issuance of the report prepared by the accountant or accounting firm regarding the financial statements or other information,  whichever occurs earlier.  2. The time limitation set forth in subsection 1 is tolled for any period during which the accountant or accounting firm conceals the act, error or omission upon which the action is founded and which is known or through the use of reasonable diligence should have been known to the accountant or the firm.  3. As used in this section, "accountant" means a person certified or registered as a public accountant pursuant to chapter 628 of NRS who holds a live permit, as defined in NRS 628.019.  (Added to NRS by 1997, 478)
NV Rev Stat § 11.208 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.208 - Action by contractor against Department of Transportation upon contract for construction, reconstruction, improvement or maintenance of highway.

An action by a contractor against the Department of Transportation upon a contract for the construction, reconstruction, improvement or maintenance of a highway must be commenced within 3 years after the date of the:  1. Completion of the contract; or  2. Determination of the engineer or decision of the Board of Directors of the Department of Transportation on an appeal of a claim arising from the contract as provided in the standard specifications for construction of roads and bridges adopted by the Department,  whichever occurs later.  (Added to NRS by 1987, 631; A 1989, 1313)
NV Rev Stat § 11.209 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.209 - Actions against original contractors by employees of subcontractors or other contractors acting under, by or for original contractors for wages, contributions, premiums, benefits or other indebtedness.

  1. No action against an original contractor for the recovery of wages due an employee of a subcontractor or other contractor acting under, by or for the original contractor, or contributions, premiums or benefits required to be made or paid on account of the employee, or any other indebtedness for labor performed by the employee owed to an employee may be commenced more than 2 years after the date the indebtedness for labor should have been made or paid by the subcontractor.  2. As used in this section, "original contractor" has the meaning ascribed to it in NRS 608.150.  (Added to NRS by 1983, 1350; A 2015, 1932; 2017, 1210)
NV Rev Stat § 11.2095 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.2095 - Action to recover payment for money owed to hospital.

  1. Except as otherwise provided in this section, an action against a person to recover payment for any amount owed to a hospital for hospital care provided to the person at the hospital must be commenced not later than 4 years after the date on which any payment that is due for the services is not paid.  2. The period provided in subsection 1 is tolled during any periods in which the hospital is awaiting a determination concerning eligibility for, or the amount of, benefits from an insurer or public program and during any periods in which payments are being made.  3. As used in this section, "hospital care" has the meaning ascribed to it in NRS 428.155.  (Added to NRS by 2007, 1498)
NV Rev Stat § 11.210 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.210 - Mutual open accounts; accrual of cause of action.

In an action brought to recover a balance due upon a mutual, open and current account, where there have been reciprocal demands between the parties, the cause of action shall be deemed to have accrued from the time of the last item proved in the account on either side.  [1911 CPA § 27; RL § 4969; NCL § 8526]
NV Rev Stat § 11.215 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.215 - Actions for damages for injury arising from sexual abuse of minor; exception for actions involving injury arising from appearance of minor in pornography.

  1. Except as otherwise provided in subsection 2 and NRS 217.007, an action to recover damages for an injury to a person arising from the sexual abuse of the plaintiff which occurred when the plaintiff was less than 18 years of age must be commenced within 20 years after the plaintiff:  (a) Reaches 18 years of age; or  (b) Discovers or reasonably should have discovered that his or her injury was caused by the sexual abuse,  whichever occurs later.  2. An action to recover damages pursuant to NRS 41.1396 must be commenced within 20 years after the occurrence of the following, whichever is later:  (a) The court enters a verdict in a related criminal case; or  (b) The victim reaches the age of 18 years.  3. As used in this section, "sexual abuse" has the meaning ascribed to it in NRS 432B.100.  (Added to NRS by 1991, 117; A 1993, 254, 455, 456; 2009, 2663; 2017, 483)
NV Rev Stat § 11.220 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.220 - Action for relief not otherwise provided for.

An action for relief, not hereinbefore provided for, must be commenced within 4 years after the cause of action shall have accrued.  [1911 CPA § 28; RL § 4970; NCL § 8527]
NV Rev Stat § 11.250 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.250 - Disabilities preventing running of statute.

If a person entitled to bring an action other than for the recovery of real property be, at the time the cause of action accrued, either:  1. Within the age of 18 years; or  2. Insane; or  3. In the custodial care of the State, if placed in such care while less than 18 years of age, except when the person is imprisoned, paroled or on probation,  the time of such disability shall not be a part of the time limited for the commencement of the action.  [1911 CPA § 34; A 1951, 54] — (NRS A 1973, 1577; 1977, 1081)
NV Rev Stat § 11.255 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.255 - Actions by or on behalf of this State.

  1. The provisions of this chapter concerning actions other than for the recovery of real property shall apply to actions brought in the name of the State, or for the benefit of the State, in the same manner as to actions by private individuals.  2. Except as provided in NRS 11.030 and 11.040, there shall be no limitation of actions brought in the name of the State, or for the benefit of the State, for the recovery of real property.  (Added to NRS by 1963, 362)
NV Rev Stat § 11.256 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.256 - Definitions.

As used in NRS 11.256 to 11.259, inclusive, unless the context otherwise requires, the words and terms defined in NRS 11.2565 and 11.257 have the meanings ascribed to them in those sections.  (Added to NRS by 2007, 646)
NV Rev Stat § 11.2565 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.2565 - "Action involving nonresidential construction" defined.

  1. "Action involving nonresidential construction" means an action that:  (a) Is commenced against a design professional; and  (b) Involves the design, construction, manufacture, repair or landscaping of a nonresidential building or structure, of an alteration of or addition to an existing nonresidential building or structure, or of an appurtenance, including, without limitation, the design, construction, manufacture, repair or landscaping of a new nonresidential building or structure, of an alteration of or addition to an existing nonresidential building or structure, or of an appurtenance.  The term includes, without limitation, an action for professional negligence.  2. As used in this section:  (a) "Appurtenance" means a structure, installation, facility, amenity or other improvement that is appurtenant to or benefits one or more nonresidential buildings or structures, but is not a part of the nonresidential building or structure. The term includes, without limitation, the parcel of real property, recreational facilities, walls, sidewalks, driveways, landscaping and other structures, installations, facilities and amenities associated with or benefiting one or more nonresidential buildings or structures.  (b) "Design professional" means a person who holds a professional license or certificate issued pursuant to chapter 623, 623A or 625 of NRS or a person primarily engaged in the practice of professional engineering, land surveying, architecture or landscape architecture.  (Added to NRS by 2007, 646)
NV Rev Stat § 11.257 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.257 - "Complainant" defined.

Complainant means a person who files an action involving nonresidential construction.  (Added to NRS by 2007, 647)
NV Rev Stat § 11.259 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.259 - Effect of compliance with or failure to comply with NRS 11.258.

  1. The court shall dismiss an action involving nonresidential construction if the attorney for the complainant fails to:  (a) File an affidavit required pursuant to NRS 11.258;  (b) File a report required pursuant to subsection 3 of NRS 11.258; or  (c) Name the expert consulted in the affidavit required pursuant to subsection 1 of NRS 11.258.  2. The fact that an attorney for a complainant has complied or failed to comply with the provisions of NRS 11.256 to 11.259, inclusive, is admissible in the action.  (Added to NRS by 2007, 648)
NV Rev Stat § 11.260 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.260 - Action to recover estate sold by guardian.

No action for the recovery of any estate sold by a guardian can be maintained by the protected person, or by any person claiming under the protected person, unless it is commenced within 3 years next after the termination of the guardianship.  [1911 CPA § 21; RL § 4963; NCL § 8520]
NV Rev Stat § 11.270 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.270 - Action to recover estate sold by executor or administrator.

No action for the recovery of any estate sold by an executor or administrator in the course of any probate proceeding can be maintained by any heir or other person claiming under the decedent, unless it be commenced within 3 years next after the sale. An action to set aside the sale may be instituted and maintained at any time within 3 years from the discovery of the fraud or other lawful grounds upon which the action is based.   [1911 CPA § 22; RL § 4964; NCL § 8521]
NV Rev Stat § 11.275 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.275 - Action against estate for which letters of administration have not been issued.

  1. Except as provided in subsection 2, no action can be maintained against an estate for which letters of administration have not been issued unless it is commenced within 3 years next after the death of the decedent.   2. This section does not affect:  (a) Any lien created by a mortgage or deed of trust which is recorded or a security agreement which is filed.  (b) The rights of any person who is in possession of personal property of the estate.  (Added to NRS by 1979, 652)
NV Rev Stat § 11.280 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.280 - Legal disability prevents running of statute.

NRS 11.260 and 11.270 shall not apply to minors or others under any legal disability to sue at the time when the right of action first accrues, but all such persons may commence an action at any time within 1 year after the removal of the disability.  [1911 CPA § 23; RL § 4965; NCL § 8522]
NV Rev Stat § 11.290 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.290 - No limitation of action for deposit of money or property; exception.

Except as otherwise provided in subsection 5 of NRS 104.3118, to actions brought to recover money or other property deposited with any bank, credit union, banker, trust company or savings and loan society, there is no limitation.   [1911 CPA § 32; RL § 4974; NCL § 8531] — (NRS A 1993, 1316; 1999, 1454)
NV Rev Stat § 11.300 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.300 - Absence from State suspends running of statute.

If, when the cause of action shall accrue against a person, the person is out of the State, the action may be commenced within the time herein limited after the person’s return to the State; and if after the cause of action shall have accrued the person departs from the State, the time of the absence shall not be part of the time prescribed for the commencement of the action.  [1911 CPA § 33; RL § 4975; NCL § 8532]
NV Rev Stat § 11.310 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.310 - Death of person entitled to bring action before limitation expires; death of person against whom an action may be brought.

  1. If the person entitled to bring an action dies before the expiration of the time limited for the commencement thereof, and the cause of action survives, an action may be commenced by the person’s representatives, after the expiration of that time, and within 1 year from the person’s death.  2. If a person against whom an action may be brought dies before the expiration of the time limited for the commencement thereof, and the cause of action survives, an action may be commenced against the person’s executors or administrators after the expiration of that time, and within 1 year after the issuing of letters testamentary or of administration; provided:  (a) The final account of such executor or administrator in the estate of such decedent be not sooner filed, and that a claim therefor be presented as required by the law governing estates of deceased persons.  (b) That no real estate of a deceased person shall be liable for the debts of the deceased person other than recorded encumbrances, unless letters testamentary or of administration be granted within 3 years from the date of the death of such decedent, any law to the contrary notwithstanding.  [Part 1911 CPA § 35; A 1925, 17; NCL § 8534]
NV Rev Stat § 11.320 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.320 - Statute suspended when person against whom cause of action exists dies out of State.

If a person against whom a cause of action exists dies without the State, the time which elapses between the person’s death and the expiration of 1 year after the issuing, within this state, of letters testamentary or letters of administration is not a part of the time limited for the commencement of an action therefor against the person’s executor or administrator.  [1911 CPA § 36; RL § 4978; NCL § 8535]
NV Rev Stat § 11.330 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.330 - Action by enemy alien; war suspends limitation.

When a person shall be an alien subject, or citizen of a country at war with the United States, the time of the continuance of the war shall not be a part of the period limited for the commencement of the action; but nothing in this section shall be so construed as to consider any citizen or person of any state engaged in rebellion against the United States Government as an alien.   [1911 CPA § 37; RL § 4979; NCL § 8536]
NV Rev Stat § 11.340 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.340 - Reversal of judgment; new action to be brought within 1 year.

If an action shall be commenced within the time prescribed therefor, and a judgment therein for the plaintiff be reversed on appeal, the plaintiff, or if the plaintiff dies and the cause of action survives, the plaintiff’s heirs or representatives, may commence a new action within 1 year after the reversal.  [1911 CPA § 38; RL § 4980; NCL § 8537]
NV Rev Stat § 11.350 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.350 - Action stayed by injunction.

When the commencement of one action shall be stayed by injunction or statutory prohibition, the time of the continuance of the injunction or prohibition shall not be part of the time limited for the commencement of the action.  [1911 CPA § 39; RL § 4981; NCL § 8538]
NV Rev Stat § 11.360 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.360 - Disability must exist when right of action accrued.

No person shall avail himself or herself of a disability, unless it existed when his or her right of action accrued.  [1911 CPA § 40; RL § 4982; NCL § 8539]
NV Rev Stat § 11.370 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.370 - Coexisting disabilities must be removed.

When two or more disabilities coexist, at the time the right of action accrues, the limitation shall not attach until they all be removed.  [1911 CPA § 41; RL § 4983; NCL § 8540]
NV Rev Stat § 11.380 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.380 - Actions against directors or stockholders of corporations.

The preceding sections of this chapter shall not affect actions against directors or stockholders of a corporation to recover a penalty or forfeiture imposed or to enforce a liability created by law; but such actions must be brought within 3 years after the discovery, by the aggrieved party, of the facts upon which the penalty or forfeiture attached, or the liability was created.  [1911 CPA § 42; RL § 4984; NCL § 8541]
NV Rev Stat § 11.390 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.390 - Acknowledgment or new promise must be in writing; exception.

No acknowledgment or promise shall be sufficient evidence of a new or continuing contract whereby to take the case out of the operation of this chapter, unless the same be contained in some writing signed by the party to be charged thereby, except as provided in NRS 11.200.  [1911 CPA § 43; RL § 4985; NCL § 8542]
NV Rev Stat § 11.500 (2021)
2021 Nevada Revised Statutes|Chapter 11 - Limitation of Actions|NRS 11.500 - Recommencement of actions dismissed for lack of subject matter jurisdiction.

  1. Notwithstanding any other provision of law, and except as otherwise provided in this section, if an action that is commenced within the applicable period of limitations is dismissed because the court lacked jurisdiction over the subject matter of the action, the action may be recommenced in the court having jurisdiction within:  (a) The applicable period of limitations; or  (b) Ninety days after the action is dismissed,  whichever is later.  2. An action may be recommenced only one time pursuant to paragraph (b) of subsection 1.  3. An action may not be recommenced pursuant to paragraph (b) of subsection 1 more than 5 years after the date on which the original action was commenced.  4. Paragraph (b) of subsection 1 does not apply to a contract that is subject to the provisions of chapter 104 of NRS.  (Added to NRS by 2003, 2134; A 2005, 247)
NV Rev Stat § 12.010 (2021)
2021 Nevada Revised Statutes|Chapter 12 - Parties|NRS 12.010 - Assignment of thing in action not to prejudice defense.

Except as provided for secured transactions in chapter 104 of NRS, in the case of an assignment of a thing in action, the action by the assignee shall be without prejudice to any setoff or other defense existing at the time of, or before notice of, the assignment; but this section shall not apply to a negotiable promissory note, or bill of exchange, transferred in good faith and upon good consideration before due.  [1911 CPA § 46; RL § 4988; NCL § 8545] — (NRS A 1965, 913)