reglab/housing_qa huggingface dataset:
WA Rev Code § 60.28.080 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.28 - Lien for Labor, Materials, Taxes on Public Works.|60.28.080 - Delay due to litigation—Change order or force account directive—Costs—Arbitration—Termination.

RCW 60.28.080 Delay due to litigation—Change order or force account directive—Costs—Arbitration—Termination.(1) If any delay in issuance of notice to proceed or in construction following an award of any public construction contract is primarily caused by acts or omissions of persons or agencies other than the contractor and a preliminary, special or permanent restraining order of a court of competent jurisdiction is issued pursuant to litigation and the appropriate public contracting body does not elect to delete the completion of the contract as provided by RCW 60.28.011(7), the appropriate contracting body will issue a change order or force account directive to cover reasonable costs incurred by the contractor as a result of such delay. These costs shall include but not be limited to contractor's costs for wages, labor costs other than wages, wage taxes, materials, equipment rentals, insurance, bonds, professional fees, and subcontracts, attributable to such delay plus a reasonable sum for overhead and profit.In the event of a dispute between the contracting body and the contractor, arbitration procedures may be commenced under the applicable terms of the construction contract, or, if the contract contains no such provision for arbitration, under the then obtaining rules of the American Arbitration Association.If the delay caused by litigation exceeds six months, the contractor may then elect to terminate the contract and to delete the completion of the contract and receive payment in proportion to the amount of the work completed plus the cost of the delay. Amounts retained and accumulated under RCW 60.28.011 shall be held for a period of forty-five days following the election of the contractor to terminate. Election not to terminate the contract by the contractor shall not affect the accumulation of costs incurred as a result of the delay provided above.(2) This section shall not apply to any contract awarded pursuant to an invitation for bid issued on or before July 16, 1973.[ 2009 c 219 § 8; 1982 c 170 § 3; 1973 1st ex.s. c 62 § 3.]NOTES:Severability—1973 1st ex.s. c 62: See note following RCW 39.04.120.Change orders due to environmental protection requirements, costs: RCW 39.04.120.
WA Rev Code § 60.32.010 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.32 - Labor Liens on Franchises, Earnings, and Property of Certain Companies.|60.32.010 - Liens authorized.

RCW 60.32.010 Liens authorized.Every person performing labor for any person, company, or corporation, in the operation of any railway, canal, or transportation company, or any water, mining, or manufacturing company, sawmill, lumber or timber company, shall have a prior lien on the franchise, earnings, and on all the real and personal property of said person, company, or corporation, which is used in the operation of its business, to the extent of the moneys due him or her from such person, company, or corporation, operating said franchise or business, for labor performed within six months next preceding the filing of his or her claim therefor, as hereinafter provided; and no mortgage, deed of trust, or conveyance shall defeat or take precedence over said lien.[ 2012 c 117 § 148; 1897 c 43 § 1; RRS § 1149.]
WA Rev Code § 60.32.020 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.32 - Labor Liens on Franchises, Earnings, and Property of Certain Companies.|60.32.020 - Notice of lien—Contents—Filing and serving.

RCW 60.32.020 Notice of lien—Contents—Filing and serving.No person shall be entitled to the lien given by RCW 60.32.010, unless he or she shall, within ninety days after he or she has ceased to perform labor for such person, company, or corporation, filed for record with the county auditor of the county in which said labor was performed, or in which is located the principal office of such person, company, or corporation in this state, a notice of claim, containing a statement of his or her demand, after deducting all just credits and offsets, the name of the person, company, or corporation, and the name of the person or persons employing claimant, if known, with the statement of the terms and conditions of his or her contract, if any, and the time he or she commenced the employment, and the date of his or her last service, and shall serve a copy thereof on said person, company, or corporation within thirty days after the same is so filed for record.Any number of claimants may join in the same notice for the purpose of filing and enforcing their liens, but the amount claimed by each claimant shall be separately stated.[ 2012 c 117 § 149; 1977 ex.s. c 176 § 1; 1897 c 43 § 2; RRS § 1150.]
WA Rev Code § 60.32.030 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.32 - Labor Liens on Franchises, Earnings, and Property of Certain Companies.|60.32.030 - Manner of serving notice.

RCW 60.32.030 Manner of serving notice.Service of notice, as herein required, may be made in the same manner as summons in civil actions.[ 1897 c 43 § 3; RRS § 1151.]NOTES:Service of summons in civil actions: RCW 4.28.080.
WA Rev Code § 60.32.040 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.32 - Labor Liens on Franchises, Earnings, and Property of Certain Companies.|60.32.040 - Manner of enforcing liens.

RCW 60.32.040 Manner of enforcing liens.Any such lien may be enforced within the same time and in the same manner as mechanics' liens are foreclosed.[ 1897 c 43 § 4; RRS § 1152.]
WA Rev Code § 60.32.050 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.32 - Labor Liens on Franchises, Earnings, and Property of Certain Companies.|60.32.050 - Receiver or assignee to pay claims first.

RCW 60.32.050 Receiver or assignee to pay claims first.Whenever a receiver or assignee is appointed for any person, company or corporation, the court shall require such receiver or assignee to pay all claims for which a lien could be filed under this chapter, before the payment of any other debts or claims, other than operating expenses.[ 1897 c 43 § 5; RRS § 1153.]
WA Rev Code § 60.34.010 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.34 - Lien of Restaurant, Hotel, Tavern, etc., Employees.|60.34.010 - Liens authorized.

RCW 60.34.010 Liens authorized.Every person performing labor in the operation of any restaurant, hotel, tavern, or other place of business engaged in the selling of prepared foods or drinks, or any hotel service employee, shall have a lien on the earnings and on all the property of his or her employer used in the operation of said business to the extent of the moneys due him or her for labor performed within three months next preceding the filing of his or her claim therefor.[ 2012 c 117 § 150; 1953 c 205 § 1.]
WA Rev Code § 60.34.020 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.34 - Lien of Restaurant, Hotel, Tavern, etc., Employees.|60.34.020 - Notice of lien—Contents—Filing and serving.

RCW 60.34.020 Notice of lien—Contents—Filing and serving.The lien claimant shall within thirty days after he or she has ceased to perform such labor, file for record with the auditor of the county in which the labor was performed a notice of claim, containing a statement of his or her demand, the name of the employer and the name of the person employing him or her, if known, with a statement of the terms and conditions of his or her contract, if any, and the time he or she commenced the employment, and the date of his or her last service, and shall serve or mail a copy thereof to said employer within said period.[ 2012 c 117 § 151; 1953 c 205 § 2.]
WA Rev Code § 60.34.030 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.34 - Lien of Restaurant, Hotel, Tavern, etc., Employees.|60.34.030 - Manner of serving notice.

RCW 60.34.030 Manner of serving notice.Service of the notice of claim may be made in the same manner as summons in civil actions.[ 1953 c 205 § 3.]NOTES:Service of summons in civil actions: RCW 4.28.080.
WA Rev Code § 60.34.040 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.34 - Lien of Restaurant, Hotel, Tavern, etc., Employees.|60.34.040 - Manner of enforcing liens—Costs.

RCW 60.34.040 Manner of enforcing liens—Costs.The lien may be enforced within the same time and in the same manner as mechanics' liens are foreclosed, when said lien is upon real property, or in the same manner as provided in chapter 60.10 RCW when the lien is upon personal property. The court may allow as part of the costs of the action the money paid for filing or recording the claim and a reasonable attorney fee.[ 1995 c 62 § 8; 1969 c 82 § 12; 1959 c 173 § 1; 1953 c 205 § 4.]
WA Rev Code § 60.34.050 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.34 - Lien of Restaurant, Hotel, Tavern, etc., Employees.|60.34.050 - Priority of lien.

RCW 60.34.050 Priority of lien.The lien created herein shall be preferred to any encumbrance which may attach after the commencement of the labor and is also preferred to any encumbrance which may have attached previously to that time, but which was not filed or recorded so as to create constructive notice thereof prior to that time, and of which the lien claimant had no notice.[ 1953 c 205 § 5.]
WA Rev Code § 60.36.010 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.36 - Lien on Vessels and Equipment.|60.36.010 - Liens created.

RCW 60.36.010 Liens created.All steamers, vessels and boats, their tackle, apparel and furniture, are liable—(1) For service rendered on board at the request of, or under contract with their respective owners, charterers, masters, agents or consignees.(2) For work done or material furnished in this state for their construction, repair or equipment at the request of their respective owners, charterers, masters, agents, consignees, contractors, subcontractors, or other person or persons having charge in whole or in part of their construction, alteration, repair or equipment; and every contractor, builder or person having charge, either in whole or in part, of the construction, alteration, repair or equipment of any steamer, vessel or boat, shall be held to be the agent of the owner for the purposes of RCW 60.36.010 and 60.36.020, and for supplies furnished in this state for their use, at the request of their respective owners, charterers, masters, agents or consignees, and any person having charge, either in whole or in part, of the purchasing of supplies for the use of any such steamer, vessel or boat, shall be held to be the agent of the owner for the purposes of RCW 60.36.010 and 60.36.020.(3) For their wharfage and anchorage within this state.(4) For nonperformance or malperformance of any contract for the transportation of persons or property between places within this state, or to or from places within this state, made by their respective owners, masters, agents or consignees.(5) For injuries committed by them to persons or property within this state, or while transporting such persons or property to or from this state. Demands for these several causes constitute liens upon all steamers, vessels and boats, and their tackle, apparel and furniture, and have priority in the order of the subdivisions hereinbefore enumerated, and have preference over all other demands; but such liens continue in force only for a period of three years from the time the cause of action accrued.[ 1901 c 24 § 1; Code 1881 § 1939; 1877 p 216 § 1; RRS § 1182. Prior: 1858 p 29 § 1.]NOTES:Lien of pilot for pilotage compensation: RCW 88.16.140.
WA Rev Code § 60.36.020 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.36 - Lien on Vessels and Equipment.|60.36.020 - Actions to enforce liens.

RCW 60.36.020 Actions to enforce liens.Such liens may be enforced, in all cases of maritime contracts or service, by a suit in admiralty, in rem, and the law regulating proceedings in admiralty shall govern in all such suits; and in all cases of contracts or service not maritime, by a civil action in any superior court of this state as provided in RCW 60.10.023.[ 1995 c 62 § 9; 1969 c 82 § 19; Code 1881 § 1940; 1877 p 216 § 2; RRS § 1183.]
WA Rev Code § 60.36.030 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.36 - Lien on Vessels and Equipment.|60.36.030 - Liens for handling cargo.

RCW 60.36.030 Liens for handling cargo.All steamers, vessels, and boats, their tackle, apparel, and furniture shall be held liable at all ports and places within this state or within the jurisdiction of the courts of this state or within the jurisdiction of the courts of the United States in said state for services rendered by stevedores, longshore workers, or others engaged in the loading, unloading, stowing, or dunnaging of cargo in or from any steamer, vessel, or boat in any harbor or at any other place within said state, or within the jurisdiction of the courts thereof as above stated, and said steamers, vessels, and boats shall further be liable as per their contracts for all services performed upon wharfs or landing places by stevedores, longshore workers, or others: PROVIDED, That such services must have been so performed in and about and be connected with the loading, unloading, dunnaging, or stowing of said cargo.[ 2013 c 23 § 123; 1901 c 75 § 1; RRS § 1184.]
WA Rev Code § 60.36.040 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.36 - Lien on Vessels and Equipment.|60.36.040 - Liens for handling cargo—Priority.

RCW 60.36.040 Liens for handling cargo—Priority.Demands for wages and all sums due under contracts or otherwise for the performance of all or any of the services mentioned in RCW 60.36.030 shall constitute liens upon all steamers, vessels, and boats, their tackle, apparel, and furniture, and shall have priority over all other demands save and excepting the demands mentioned in RCW 60.36.010 (1), (2), and (3), to which said demands the lien hereby provided shall be subordinate: PROVIDED, That such liens shall only continue in force for the period of three years from the date when such work was done or the last services performed by such stevedores, longshore workers, or others.[ 2013 c 23 § 124; 1901 c 75 § 2; RRS § 1185.]
WA Rev Code § 60.36.050 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.36 - Lien on Vessels and Equipment.|60.36.050 - Liens for handling cargo—Foreclosure.

RCW 60.36.050 Liens for handling cargo—Foreclosure.The liens hereby created may be foreclosed as provided in RCW 60.10.023.[ 1995 c 62 § 10; 1969 c 82 § 13; 1901 c 75 § 3; RRS § 1186.]
WA Rev Code § 60.36.060 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.36 - Lien on Vessels and Equipment.|60.36.060 - Lien for breach of contract for towing, dunnaging, stevedoring, etc.

RCW 60.36.060 Lien for breach of contract for towing, dunnaging, stevedoring, etc.Whenever the owner, charterer, or any person or corporation operating, managing or controlling any steamship, vessel or boat shall wilfully fail, neglect or refuse to carry out or perform any express contract or portion thereof for the towing, loading, unloading, dunnaging or stevedoring of such steamship, vessel or boat, any person or persons, firm or corporation sustaining thereby any loss or damage which is capable of definite ascertainment shall have a lien upon such steamship, vessel or boat for said loss or damage. The rank and priority of the lien hereby created and the manner of its enforcement shall be fixed, controlled and regulated by the provisions of the existing law pertaining to liens for similar services already performed.[ 1903 c 149 § 1; RRS § 1187.]
WA Rev Code § 60.40.020 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.40 - Lien for Attorney's Fees.|60.40.020 - Proceedings to compel delivery of money or papers.

RCW 60.40.020 Proceedings to compel delivery of money or papers.When an attorney refuses to deliver over money or papers, to a person from or for whom he or she has received them in the course of professional employment, whether in an action or not, he or she may be required by an order of the court in which an action, if any, was prosecuted, or if no action was prosecuted, then by order of any judge of a court of record, to do so within a specified time, or show cause why he or she should not be punished for a contempt.[ 2012 c 117 § 152; Code 1881 § 3287; 1863 p 406 § 13; RRS § 137.]
WA Rev Code § 60.40.030 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.40 - Lien for Attorney's Fees.|60.40.030 - Procedure when lien is claimed.

RCW 60.40.030 Procedure when lien is claimed.If, however, the attorney claim a lien, upon the money or papers, under the provisions of *this chapter, the court or judge may: (1) Impose as a condition of making the order, that the client give security in a form and amount to be directed, to satisfy the lien, when determined in an action; (2) summarily to inquire into the facts on which the claim of a lien is founded, and determine the same; or (3) to refer it, and upon the report, determine the same as in other cases.[Code 1881 § 3288; 1863 p 406 § 14; RRS § 138.]NOTES:*Reviser's note: "this chapter" appeared in section 3288, chapter 250 of the Code of 1881, the lien sections of which are codified as chapter 60.40 RCW.
WA Rev Code § 60.42.020 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.42 - Commercial Real Estate Broker Lien Act.|60.42.020 - Disputed claim—Order to show cause—Hearing.

RCW 60.42.020 Disputed claim—Order to show cause—Hearing.(1) An owner of commercial real estate subject to a recorded notice of claim of lien against proceeds under this chapter, who disputes the broker's claim in the notice of claim of lien against proceeds, may apply by motion to the superior court for the county where the commercial real estate, or some part thereof, is located for an order directing the broker to appear before the court at a time no earlier than seven nor later than fifteen days following the date of service of the motion and order on the broker, to show cause as to why the relief requested should not be granted. The motion must state the grounds upon which relief is asked and must be supported by the affidavit of the owner setting forth a concise statement of the facts upon which the motion is based.(2) The order to show cause must clearly state that if the broker fails to appear at the time and place noted, the notice of claim of lien against proceeds must be released, with prejudice, and the broker must be ordered to pay the costs requested by the owner, including reasonable attorneys' fees.(3) If, following a hearing on the matter, the court determines that the owner is not a party to an agreement which will result in the owner being obligated to pay to the broker a commission pursuant to the terms of a commission agreement, the court shall issue an order releasing the notice of claim of lien against proceeds and awarding costs and reasonable attorneys' fees to the owner to be paid by the broker. If the court determines that the owner is a party to an agreement which will result in the owner being obligated to pay to the broker a commission pursuant to the terms of a commission agreement, the court shall issue an order so stating and awarding costs and reasonable attorneys' fees to the broker, to be paid by the owner. Such orders are final judgments.(4) Proceedings under this section shall not affect other rights and remedies available to the parties under this chapter or otherwise.[ 1997 c 315 § 3.]
WA Rev Code § 60.42.030 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.42 - Commercial Real Estate Broker Lien Act.|60.42.030 - Lien on net rental proceeds—Order to show cause—Hearing.

RCW 60.42.030 Lien on net rental proceeds—Order to show cause—Hearing.(1) If a broker has a lien on net rental proceeds pursuant to RCW 60.42.010(2), and the broker has recorded a notice of claim of lien against proceeds and otherwise complied with the requirements of this chapter, the broker may apply by motion to the superior court for the county where the commercial real estate, or some part thereof, is located, for an order directing the owner to appear before the court at a time no earlier than seven nor later than fifteen days following the date of service of the motion and order on the owner, and show cause as to why the relief requested should not be granted. The motion must state the grounds upon which relief is asked, and must be supported by the affidavit of the broker setting forth a concise statement of the facts upon which the motion is based.(2) The order to show cause must clearly state that if the owner fails to appear at the time and place noted, the broker shall be entitled to an order enjoining the owner from paying the net rental proceeds from such lease to any party other than the broker, and that the owner shall be ordered to pay the costs requested by the broker, including reasonable attorneys' fees.(3) If, following a hearing on the matter, the court determines that the owner is, or was, a party to an agreement for the lease of commercial real estate, which did or will result in the owner being obligated to pay to the broker a commission pursuant to the terms of a commission agreement, the court shall issue an order enjoining the owner from paying the net rental proceeds from such lease to any party other than the broker. The court shall also order the owner to pay such net rental proceeds to the broker and award costs and reasonable attorneys' fees to the broker, to be paid by the owner. If the court determines that the owner is not, or was not, a party to an agreement for the lease of commercial real estate, which did or will result in the owner being obligated to pay to the broker a commission pursuant to the terms of a commission agreement, the court shall issue an order so stating and awarding costs and reasonable attorneys' fees to the owner, to be paid by the broker. Such orders are final judgments.(4) Proceedings under this section shall not affect other rights and remedies available to the parties under this chapter or otherwise.[ 1997 c 315 § 4.]
WA Rev Code § 60.42.040 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.42 - Commercial Real Estate Broker Lien Act.|60.42.040 - Priority of lien claims.

RCW 60.42.040 Priority of lien claims.All statutory liens, consensual liens, mortgages, deeds of trust, assignments of rents, and other encumbrances, including all advances or charges made or accruing thereunder, whether voluntary or obligatory, and all modifications, extensions, renewals, and replacements thereof, recorded prior to the recording of a notice of claim of lien against proceeds have priority over a lien created under this chapter. A prior recorded lien includes, without limitation, a valid material supplier's or mechanic's lien claim that is recorded after the recording of the broker's notice of claim of lien against proceeds but which relates back to a date prior to the recording date of the broker's notice of claim of lien against proceeds.[ 2013 c 23 § 125; 1997 c 315 § 5.]
WA Rev Code § 60.42.050 (2021)
2021 Revised Code of Washington|Title 60 - Liens|Chapter 60.42 - Commercial Real Estate Broker Lien Act.|60.42.050 - Deposit made pending resolution of amounts due—Recording of receipt—Release of notice of claim of lien.

RCW 60.42.050 Deposit made pending resolution of amounts due—Recording of receipt—Release of notice of claim of lien.A notice of claim of lien against proceeds recorded under this chapter must be released without further act, upon the recording of a receipt showing the deposit with the superior court of the county in which the commercial real estate, or some part thereof, is located, of an amount equal to one and one-quarter times the amount of the lien claimed. The receipt shall be recorded in the office in which the notice of claim was recorded. The amount of the deposit in the superior court shall be held pending a resolution of amounts due to the broker and the owner.[ 1997 c 315 § 6.]