reglab/housing_qa huggingface dataset:
OR Rev Stat § 701.565 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.565 - Notice of defect requirement; contents; mailing.

(1) Except as provided in ORS 701.600, an owner may not compel arbitration or commence a court action against a contractor, subcontractor or supplier to assert a claim arising out of or related to any defect in the construction, alteration or repair of a residence or in any system, component or material incorporated into a residence located in this state unless the owner has sent that contractor, subcontractor or supplier a notice of defect as provided in this section and has complied with ORS 701.575. (2) An owner must send a notice of defect by registered or certified mail, return receipt requested. If a notice of defect is sent to a contractor or subcontractor, the owner must send the notice to the last known address for the contractor or subcontractor as shown in the records of the Construction Contractors Board. If a notice of defect is sent to a supplier, the owner must send the notice to the Oregon business address of the supplier or, if none, to the registered agent of the supplier. (3) A notice of defect sent by an owner must include: (a) The name and mailing address of the owner or the owner’s legal representative, if any; (b) A statement that the owner may seek to compel arbitration or bring a court action against the contractor, subcontractor or supplier; (c) The address and location of the affected residence; (d) A description of: (A) Each defect; (B) The remediation the owner believes is necessary; and (C) Any incidental damage not curable by remediation as described in subparagraph (B) of this paragraph; and (e) Any report or other document evidencing the existence of the defects and any incidental damage. [2003 c.660 §2; 2011 c.268 §1] Note: See note under 701.560.
OR Rev Stat § 701.575 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.575 - Availability of residence; scope of inspection; report of inspection results.

(1) An owner sending a notice of defect under ORS 701.565 shall make the residence available for visual examination pursuant to any written request sent under ORS 701.570. The owner shall make the residence available for visual examination, during normal business hours or as otherwise agreed, not later than 20 days after receiving the written request for visual examination. (2) An owner sending a notice of defect under ORS 701.565 shall make the residence available for an inspection pursuant to any written request sent under ORS 701.570. The owner shall make the residence available for inspection during normal business hours or at a time that is mutually agreeable to the owner and the requester. (3) An inspection by a contractor, subcontractor or supplier may include any reasonable measures, including testing, for determining the nature, cause and extent of the defects described in the notice of defect or incidental damage and the nature and extent of the necessary remediation. Unless the contractor, subcontractor or supplier conducting the inspection and the owner agree otherwise, the contractor, subcontractor or supplier conducting the inspection shall repair any damage caused by the inspection. Any damage caused by the inspection that is not repaired may be sought as incidental damage in any subsequent arbitration or court action by an owner against the contractor, subcontractor or supplier conducting the inspection. (4) A contractor, subcontractor or supplier that requests to inspect a residence must include as part of the written response of the contractor, subcontractor or supplier under ORS 701.570, a written report or other document evidencing the result of the inspection and the existence or nonexistence of the defects described in the notice of defect or discovered during the inspection. [2003 c.660 §4] Note: See note under 701.560.
OR Rev Stat § 701.585 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.585 - Effect of notice of defect on time for commencing court action.

(1) If an owner sends a contractor, subcontractor or supplier a notice of defect within the time allowed for the owner to commence a court action against that contractor, subcontractor or supplier for a claim described in ORS 701.565, the time for the owner to commence the action shall be extended, notwithstanding any statute of limitation or statute of ultimate repose, until the later of: (a) One hundred and twenty days after the owner receives a written response from the contractor, subcontractor or supplier that received the notice of defect if the written response does not contain a written offer to perform remediation or pay monetary compensation for one or more of the defects or incidental damage described in the notice of defect; (b) One hundred and twenty days after the owner rejects a written offer by any contractor, subcontractor or supplier to perform remediation or pay monetary compensation for one or more of the defects or incidental damage described in the notice of defect; or (c) Thirty days after the date specified in an accepted written offer by which the offering contractor, subcontractor or supplier is to complete the remediation or complete payment of monetary compensation for one or more of the defects and any incidental damage described in the notice of defect. (2) Subsection (1) of this section does not shorten or terminate the time for bringing a claim in accordance with applicable statutes of ultimate repose and statutes of limitation. (3) Delivery of a secondary notice sent by a contractor, subcontractor or supplier under ORS 701.570 does not act to toll the expiration of any right of the owner to commence a court action against the recipient of the secondary notice. (4) Any remediation performed pursuant to an accepted offer made under ORS 701.570 does not constitute a new performance and, for purposes of ORS 12.135, relates back to the earliest date of substantial completion or abandonment of the construction, alteration or repair of the improvement to real property. [2003 c.660 §6] Note: See note under 701.560.
OR Rev Stat § 701.595 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.595 - Failure to follow notice of defect procedure.

If an owner compels arbitration or commences a court action against any contractor, subcontractor or supplier to assert a claim arising out of or related to the construction, alteration or repair of a residence located in this state and the owner has not followed the procedure set forth in ORS 701.565 and 701.575, the arbitrator or court must dismiss the arbitration or action without prejudice. The owner may not commence a new arbitration or action unless the owner follows the procedure set forth in ORS 701.565 and 701.575. [2003 c.660 §8] Note: See note under 701.560.
OR Rev Stat § 701.600 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.600 - Nonapplicability of ORS 701.560 to 701.595 and 701.605.

ORS 701.560 to 701.595 and 701.605 do not apply: (1) To personal injury or death claims. (2) To claims or complaints filed pursuant to ORS 671.695 or 701.139. (3) To claims against a person registered under ORS 671.010 to 671.220. (4) To complaints filed in a small claims department established in a justice court or circuit court as described in ORS 55.011. (5) To counterclaims or other responses to a contractor, subcontractor or supplier claim, arbitration demand or complaint that arises out of, or is related to, a contract for the construction, alteration or repair of a residence or a system, component or material incorporated into a residence. [2003 c.660 §9; 2007 c.149 §10; 2007 c.793 §25; 2011 c.268 §3; 2013 c.196 §23] Note: See note under 701.560.
OR Rev Stat § 701.605 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.605 - Recording of written warranty agreement.

(1) To facilitate the handling of warranty work or remediation of defects to a new commercial or residential structure or a zero-lot-line dwelling, a contractor who builds the structure may present for recording in the deed records of the county in which the new structure is built a written warranty agreement that: (a) Is signed by the contractor and the original owner of the new structure; (b) Sets forth any express warranties furnished by the contractor; and (c) Contains the names of the contractor and the original property owner, the title of the document, a legal description of the property and acknowledgment of the signatures of the parties in the same manner as the parties to a deed are acknowledged. (2) The warranties set forth in the recorded warranty agreement: (a) Benefit and burden subsequent owners of the structure. (b) Cease to affect title to the property 10 years after the date the instrument is recorded. [2005 c.169 §2; 2007 c.648 §29] Note: See note under 701.560.
OR Rev Stat § 701.610 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.610

[2013 c.300 §5a; renumbered 701.501 in 2015]
OR Rev Stat § 701.620 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.620 - Definitions for ORS 701.620 to 701.640.

As used in ORS 701.620 to 701.640: (1) "Construction contract" means a written or oral construction agreement, including all drawings, specifications and addenda relating to: (a) Excavating, landscaping, demolishing and detaching existing structures, leveling, filling in and other preparation of land for the making and placement of a building, structure or superstructure; (b) Creation or making of a building, structure or superstructure; and (c) Alteration, partial construction and repairs done in and upon a building, structure or superstructure. (2) "Contractor" has the meaning given that term in ORS 87.005. (3) "Days" means calendar days. (4) "Material supplier" means any person providing materials or products under a construction contract by oral authorization, written contract, purchase order, price agreement, rental agreement or other contractual means. (5) "Original contractor" has the meaning given that term in ORS 87.005. (6) "Owner" has the meaning given that term in ORS 701.410. (7) "Subcontractor" has the meaning given that term in ORS 87.005. [2003 c.675 §54; 2011 c.553 §1] Note: 701.620 to 701.645 were enacted into law by the Legislative Assembly but were not added to or made a part of ORS chapter 701 or any series therein by legislative action. See Preface to Oregon Revised Statutes for further explanation.
OR Rev Stat § 701.640 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.640 - Prohibition against contrary provisions, covenants or clauses.

(1) A construction contract may not include any provision, covenant or clause that: (a) Makes the construction contract subject to the laws of another state or that requires any litigation, arbitration or other dispute resolution proceeding arising from the construction contract to be conducted in another state; or (b) States that a party to the construction contract cannot suspend performance under the construction contract or terminate the construction contract if another party to the construction contract fails to make prompt payments under the construction contract pursuant to ORS 701.620 to 701.640. (2) Any provision, covenant or clause described in subsection (1) of this section is void and unenforceable. [2003 c.675 §58; 2011 c.553 §5] Note: See note under 701.620.
OR Rev Stat § 701.645 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.645 - Contracts and housing not subject to ORS 701.620 to 701.640.

ORS 701.620 to 701.640 do not apply to: (1) A contract for the construction, alteration, repair, maintenance, moving or demolition of a building that is subject to the Low-Rise Residential Dwelling Code; (2) A public contract under ORS 279.835 to 279.855 or ORS chapter 279A, 279B or 279C; or (3) Housing in which all or part of the dwelling units are reserved for rental to persons having an income equal to or less than 80 percent of the median household income for the area as determined by the Housing and Community Services Department. [2003 c.675 §59; 2003 c.794 §331d] Note: See note under 701.620.
OR Rev Stat § 701.900 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.900

[1989 c.928 §31; 1999 c.402 §40; renumbered 701.002 in 2001]
OR Rev Stat § 701.990 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.990 - Criminal penalties.

(1) Violation of ORS 701.021 is a Class A misdemeanor. (2) The intentional use of a contractor’s license number without the authorization of the licensed contractor is a Class A misdemeanor. (3) Use of a contractor’s license number, with or without the authorization of the licensed contractor, with the intent to deceive the public is a Class A misdemeanor. [1971 c.740 §22; 1999 c.344 §7; 2001 c.104 §282; 2001 c.850 §7; 2007 c.836 §37]
OR Rev Stat § 701.992 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.992 - Civil penalties and other sanctions; enforcement.

(1) Except as provided in subsections (4) and (5) of this section, any person who violates any provision of this chapter or any rule adopted by the Construction Contractors Board shall forfeit and pay into the General Fund of the State Treasury a civil penalty in an amount determined by the board of not more than $5,000 for each offense. (2) Civil penalties under this section shall be imposed as provided in ORS 183.745. (3) The provisions of this section are in addition to and not in lieu of any other penalty or sanction provided by law. (4) The board shall impose sanctions for violation of ORS 701.098 (1)(h) on both the person to whom the contract is awarded and the person who awards the contract as follows: (a) A penalty not less than $500 nor more than $1,000 for the first offense; (b) A penalty not less than $1,000 nor more than $2,000 for the second offense; (c) Suspension of the person’s license for six months for a third offense; (d) Suspension of the person’s license for three years for a fourth offense; and (e) Revocation of the person’s license for a fifth offense. (5) The board may impose a civil penalty not to exceed $100 for each violation of ORS 87.007 (3). [1971 c.740 §21; 1979 c.874 §5; 1981 c.618 §14; 1983 c.616 §16; 1983 c.696 §27; 1991 c.734 §90; 1995 c.216 §4; 1995 c.771 §6; 1999 c.402 §41; 2003 c.14 §441; 2003 c.778 §7; 2005 c.432 §17; 2007 c.836 §38]
OR Rev Stat § 701.995 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 701 - Construction Contractors and Contracts|Section 701.995 - Civil penalties for violations related to lead-based paint activities; reporting of penalties and sanctions.

(1) A person who violates any provision of, or any rule adopted under, ORS 701.505 to 701.515 shall pay to the Construction Contractors Board Lead-Based Paint Activities Fund established under ORS 701.520 a civil penalty of not more than $5,000 for each violation. (2) Civil penalties under this section shall be imposed as provided in ORS 183.745. (3) A civil penalty imposed under this section is in addition to and not in lieu of any other penalty or sanction provided by law. (4) The board shall report all civil penalties or sanctions imposed under this section to each of the following state agencies: (a) The Oregon Health Authority; (b) The Occupational Safety and Health Division of the Department of Consumer and Business Services; and (c) The Department of Environmental Quality. [2009 c.757 §10; 2009 c.828 §69] Note: 701.995 was enacted into law by the Legislative Assembly but was not added to or made a part of ORS chapter 701 or any series therein by legislative action. See Preface to Oregon Revised Statutes for further explanation.
OR Rev Stat § 702.001 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.001 - Revised Uniform Athlete Agents Act.

ORS 702.005 to 702.065, 702.991 and 702.994 shall be known and may be cited as the Revised Uniform Athlete Agents Act. [2017 c.113 §1]
OR Rev Stat § 702.019 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.019 - Temporary certificate of registration.

The Department of Education may issue a temporary certificate of registration while an application for registration or renewal of registration is pending. [2005 c.525 §6]
OR Rev Stat § 702.023 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.023 - Fees.

(1) An application for registration or renewal of registration must be accompanied by a fee in the following amount: (a) $250 for an initial application for registration; (b) $150 for an application for registration based upon a certificate of registration or licensure issued by another state; (c) $150 for an application for renewal of registration; or (d) $150 for an application for renewal of registration based upon an application for renewal of registration or licensure submitted in another state. (2) Any fees collected under this section by the Department of Education shall be deposited in the Department of Education Account established under ORS 326.115. [2005 c.525 §7]
OR Rev Stat § 702.027 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.027 - Restrictions on athlete agents.

An athlete agent may not intentionally: (1) Initiate contact with a student athlete or, if the athlete is a minor, a parent or guardian of the athlete unless registered under ORS 702.005 to 702.065, 702.991 and 702.994; (2) Refuse or fail to retain or permit inspection of the records required to be retained by ORS 702.059; (3) Fail to register when required by ORS 702.012; (4) Provide materially false or misleading information in an application for registration or renewal of registration; (5) Predate or postdate a written agency contract; (6) Fail to notify a student athlete or, if the athlete is a minor, a parent or guardian of the athlete before the student athlete, parent or guardian enters into an agency contract for a particular sport that entering into the agency contract may make the student athlete ineligible to participate as a student athlete in that sport; or (7) Represent a student athlete who is enrolled in a post-secondary institution of education, if the athlete agent represented a post-secondary institution of education at any time in the preceding four years. [1999 c.1079 §6; 2005 c.525 §8; 2013 c.54 §5; 2017 c.113 §9; 2021 c.422 §2]
OR Rev Stat § 702.029 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.029 - Notice to athletic director regarding contact with student athlete.

(1) As used in this section, "communicating or attempting to communicate" means contacting or attempting to contact by an in-person meeting, a record or any other method that conveys or attempts to convey a message. (2) Before communicating or attempting to communicate with a student athlete or, if the athlete is a minor, a parent or guardian of the athlete, an athlete agent shall provide written notice to the athletic director of the educational institution at which the student athlete is enrolled. Notice provided under this subsection must state that the athlete agent intends to communicate with: (a) The athlete or, if the athlete is a minor, a parent or guardian of the athlete, to influence the athlete or parent or guardian to enter into an agency contract; or (b) Another individual to have that individual influence the athlete or, if the athlete is a minor, the parent or guardian of the athlete to enter into an agency contract. (3) Within 10 days after a communication or attempt to communicate with an athlete agent is initiated by a student athlete or another individual on behalf of the athlete, the agent shall provide written notice to the athletic director of any educational institution at which the athlete is enrolled. (4) The written notice required by this section may be delivered personally or by registered or certified mail, electronic mail, facsimile or other electronic means. (5) An educational institution that becomes aware of a violation of ORS 702.005 to 702.065, 702.991 and 702.994 by an athlete agent shall notify the Department of Education and any professional league or players association with which the institution is aware the agent is licensed or registered of the violation. [2013 c.54 §3; 2017 c.113 §7]
OR Rev Stat § 702.030 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.030 - Restrictions on inducement of student athletes; exceptions.

(1) Except as otherwise provided in subsection (2) of this section, an athlete agent, with the intent to induce a student athlete or, if the athlete is a minor, a parent or guardian of the athlete to enter into an agency contract, may not take any of the following actions or encourage any other individual to take or assist any other individual in taking any of the following actions on behalf of the agent: (a) Give any materially false or misleading information or make a materially false promise or representation. (b) Furnish anything of value to the student athlete before the student athlete enters into an agency contract. (c) Furnish anything of value to any individual other than the student athlete or another registered athlete agent. (2) An athlete agent, who is certified to be an athlete agent in a particular sport by a national association that promotes or regulates intercollegiate athletics and establishes eligibility standards for participation by a student athlete in that sport, may pay expenses incurred before the signing of an agency contract to: (a) A student athlete; (b) A parent or guardian of the student athlete; or (c) An individual who is a member of a class of individuals authorized to receive payment for the expenses by the national association that certified the agent if the expenses are: (A) For the benefit of a student athlete who is a member of a class of student athletes authorized to receive the benefit by the national association that certified the athlete agent; (B) Of a type authorized to be paid by an athlete agent by the national association that certified the athlete agent; and (C) For a purpose authorized by the national association that certified the athlete agent. [2005 c.525 §11; 2017 c.113 §10; 2019 c.92 §1]
OR Rev Stat § 702.052 (2021)
2021 Oregon Revised Statutes|Volume : 17 - Occupations|Chapter 702 - Student Athlete|Section 702.052 - Right to cancel contract.

(1) A student athlete or, if the athlete is a minor, the parent or guardian of the athlete may cancel an agency contract by giving notice of the cancellation to the athlete agent in a record within 14 days after entering into the agency contract. (2) The right of a student athlete or, if the athlete is a minor, the parent or guardian of the athlete to cancel an agency contract under this section may not be waived. (3) If a student athlete, parent or guardian cancels an agency contract, the student athlete, parent or guardian is not required to pay any consideration under the contract or to return any consideration received from the athlete agent to induce the student athlete to enter into the contract. [1999 c.1079 §10; 2005 c.525 §15; 2013 c.54 §7; 2017 c.113 §8]