reglab/housing_qa huggingface dataset:
WY Stat § 16-5-412 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 5 - Public Securities|Article 4 - Bond Anticipation Notes|Section 16-5-412 - Scope, Authority and Effect of Provisions.

16-5-412. Scope, authority and effect of provisions.| (a) This act, without reference to other statutes of the state except as herein otherwise specifically provided, constitutes full authority for the authorization and issuance of anticipation notes hereunder. No other act or law with regard to the authorization or issuance of securities by any issuer that in any way impedes or restricts the carrying out of the acts herein authorized to be done shall be construed as applying to any proceedings taken hereunder or acts done pursuant hereto, except as otherwise expressly provided herein. The powers conferred by this act shall be in addition to and supplemental to, and not in substitution for, and the limitations imposed by this act shall not affect the powers conferred by any other law applicable to any issuer except as otherwise provided herein.  (b) Anticipation notes issued by the University of Wyoming shall be governed by W.S. 21-17-402 through 21-17-450, the University Securities Law.
WY Stat § 16-5-501 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 5 - Public Securities|Article 5 - General Provisions as to Form and Manner of Issuance, Payment and Transfer of Public Securities|Section 16-5-501 - Applicability.

16-5-501. Applicability.| This article applies to bonds, notes, warrants, certificates or other securities evidencing loans or the advancement of monies, heretofore or hereafter authorized to be issued by or on behalf of the state or any political subdivision, district, public board, agency, commission, authority or other public body corporate in the state pursuant to any general or special act or pursuant to any lawful legislative or home rule provision.
WY Stat § 16-5-502 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 5 - Public Securities|Article 5 - General Provisions as to Form and Manner of Issuance, Payment and Transfer of Public Securities|Section 16-5-502 - Form, Payment and Transfer of Securities.

16-5-502. Form, payment and transfer of securities.| (a) The securities described in W.S. 16-5-501 shall be in registered or bearer form, with or without interest coupons, be subject to such conditions for transfer, be subject to such provisions for conversion as to denomination or to bearer or registered form, be made registrable or payable, or both, by the treasurer or other officer of the issuing entity, or by trustee, registrar, paying agent or transfer agent within or without the state of Wyoming, be issued, transferred and registered by book entry, be in a denomination, bear such dates, signatures and authentications, and be held in custody by a depository within or without the state of Wyoming, all as may be determined by the entity or the governing body of the entity authorized or empowered to issue the securities. Payment at designated due dates or in installments may be required by the authorizing proceedings to be by check, draft or other medium of payment and need not be conditioned upon presentation of any security or coupon.  (b) Bonds issued by or on behalf of a political subdivision of the state may be issued as digital securities, as defined by W.S. 34-29-101(a)(iii), if the bonds are otherwise issued in accordance with all applicable state and federal laws and regulations.
WY Stat § 16-5-503 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 5 - Public Securities|Article 5 - General Provisions as to Form and Manner of Issuance, Payment and Transfer of Public Securities|Section 16-5-503 - Determination by Resolution or Ordinance.

16-5-503. Determination by resolution or ordinance.| The determination of the body authorized or empowered to issue securities required by W.S. 16-5-502 shall be made in the resolution or ordinance authorizing the issuance of the securities or in any supplemental ordinance, resolution or other instrument.
WY Stat § 16-5-504 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 5 - Public Securities|Article 5 - General Provisions as to Form and Manner of Issuance, Payment and Transfer of Public Securities|Section 16-5-504 - No Restriction on Other Acts.

16-5-504. No restriction on other acts.| This article as to the matters contained herein shall constitute an additional and separate grant of powers and these powers may be exercised without regard to provisions concerning matters in any other act but this article is not a restriction or limitation on the exercise of powers by an issuing entity under any other act.
WY Stat § 16-6-103 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-103 - Limitation on Subcontracting by Resident Contractors.

16-6-103. Limitation on subcontracting by resident contractors.| A successful resident bidder shall not subcontract more than thirty percent (30%) of the work covered by his contract to nonresident contractors.
WY Stat § 16-6-104 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-104 - Preference for Wyoming Materials Required in Contracts.

16-6-104. Preference for Wyoming materials required in contracts.| Wyoming made materials and products, and Wyoming suppliers of products and materials of equal quality and desirability shall have preference over materials or products produced or supplied outside the state and any contract let shall so provide. The preference created by this section shall be applied in a manner identical to the preference for residence contractors in W.S. 16-6-102.
WY Stat § 16-6-105 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-105 - Preference for Wyoming Materials and Wyoming Agricultural Products Required in Public Purchases; Exception; Cost Differential; Definition.

16-6-105. Preference for Wyoming materials and Wyoming agricultural products required in public purchases; exception; cost differential; definition.| (a) A five percent (5%) materials preference for Wyoming materials shall be applied in public purchases, subject to the following:  (i) The preference requirement shall apply to all public entities;  (A) Repealed by Laws 2020, ch. 31, § 2.  (B) Repealed by Laws 2020, ch. 31, § 2.  (C) Repealed by Laws 2020, ch. 31, § 2.  (ii) As used in this section, "materials" means supplies, material, agricultural products, equipment, machinery and provisions to be used in a public work, including the regular maintenance and upkeep of a public work;  (iii) The preference shall be applied in favor of materials that are produced, manufactured or grown in this state, or that are supplied by a resident of the state who is competent and capable to provide the materials within the state of Wyoming;  (iv) Preference shall not be granted for materials of inferior quality to those offered by competitors outside of the state.  (b) As used in this section, "agricultural products" means any horticultural, viticultural, vegetable product, livestock, livestock product, bees or honey, poultry or poultry product, sheep or wool product, timber or timber product.
WY Stat § 16-6-106 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-106 - Statement of Wyoming Materials Preference in Requests for Bids and Proposals.

16-6-106. Statement of Wyoming materials preference in requests for bids and proposals.| All requests by a public entity for bids and proposals for materials, supplies, agricultural products, equipment, machinery and public works shall contain the words "preference is hereby given to materials, supplies, agricultural products, equipment, machinery and provisions produced, manufactured or grown in Wyoming, or supplied by a resident of the state, quality being equal to articles offered by the competitors outside of the state".
WY Stat § 16-6-107 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-107 - Wyoming Materials Preference Required in Public Works; Exception.

16-6-107. Wyoming materials preference required in public works; exception.| All public works in this state shall be constructed and maintained using materials produced or manufactured in Wyoming if Wyoming materials are suitable and can be furnished in marketable quantities. Preference shall not be granted for materials of an inferior quality to those offered by competitors outside of the state, but a differential of five percent (5%) shall be allowed in cost of materials produced or manufactured in Wyoming.
WY Stat § 16-6-108 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-108 - Governing of Federal Funds by Federal Law.

16-6-108. Governing of federal funds by federal law.| The operation of this act upon the letting of any public works contract above mentioned, in connection with which, funds are granted or advanced by the United States of America, shall be subject to the effect, if any, of related laws of the United States and valid rules and regulations of federal agencies in charge, governing use and payment of the federal funds.
WY Stat § 16-6-109 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-109 - Use of Insurance for Rebuilding State Structures.

16-6-109. Use of insurance for rebuilding state structures.| When buildings belonging to the state are destroyed, the insurance on the buildings shall be collected by the state treasurer. The governing board of the state institution suffering the loss may draw on the state treasurer for the amount of money collected and use the insurance money for the rebuilding of the structure destroyed if, in the opinion of the governing board, the structure should be rebuilt.
WY Stat § 16-6-110 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-110 - Limitation on Work Hours; Overtime; Exceptions.

16-6-110. Limitation on work hours; overtime; exceptions.| (a) No person shall require laborers, workmen or mechanics to work more than eight (8) hours in any one (1) calendar day or forty (40) hours in any one (1) week upon any public works of a public entity except as hereafter authorized. A laborer, workman or mechanic may agree to work more than eight (8) hours per day or more than forty (40) hours in any week, provided the laborer, workman or mechanic shall be paid at the rate of one and one-half (1 1/2) times the regularly established hourly rate for all work in excess of forty (40) hours in any one (1) week. This section does not apply:  (i) In case of emergency caused by fire, flood or danger to life or property; or  (ii) To work upon public or military works or defenses in time of war.
WY Stat § 16-6-111 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-111 - Penalty for Violating Work Hours Provisions.

16-6-111. Penalty for violating work hours provisions.| Any person who violates this act is guilty of a misdemeanor punishable by a fine of not more than seven hundred fifty dollars ($750.00).
WY Stat § 16-6-112 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-112 - Contractor's Performance and Payment Bond or Other Guarantee; When Required; Conditions; Amount; Approval; Filing; Enforcement Upon Default.

16-6-112. Contractor's performance and payment bond or other guarantee; when required; conditions; amount; approval; filing; enforcement upon default.| (a) Any contract entered into with a public entity for a public work where the contract price exceeds one hundred fifty thousand dollars ($150,000.00), shall require any contractor before beginning work under the contract to furnish the public entity a bond. If the contract price is one hundred fifty thousand dollars ($150,000.00) or less, the public entity may require the contractor to furnish any other form of guarantee approved by the public entity. The bond or other form of guarantee shall be:  (i) Available and with such conditions that allow for the payment of all taxes, excises, licenses, assessments, contributions, penalties and interest lawfully due the state or any political subdivision;  (ii) For the use and benefit of any person performing any work or labor or furnishing any material or goods of any kind which were used in the execution of the contract, conditioned for the performance and completion of the contract according to its terms, compliance with all the requirements of law and payment as due of all just claims for work or labor performed and materials furnished in the execution of the contract;  (iii) In an amount not less than one hundred percent (100%) of the contract price unless the price is one hundred fifty thousand dollars ($150,000.00) or less, in which case the public entity may fix a sufficient amount;  (iv) Approved by and filed with the appropriate officer, agent, governing body or other designee of the public entity.  (b) A bond or other guarantee satisfactory to the public entity shall include the obligations specified under subsection (a) of this section even though not expressly written into the guarantee.  (c) In default of the prompt payment of all obligations under the guarantee, a direct proceeding may be brought in any court of competent jurisdiction by the authorized officer or agency to enforce payment. The right to proceed in this matter is cumulative and in addition to other remedies provided by law.
WY Stat § 16-6-113 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-113 - Contractor's Performance and Payment Bond or Other Guarantee; Right of Action; Notice to Obligee; Intervention by Interested Parties; Pro Rata Distribution.

16-6-113. Contractor's performance and payment bond or other guarantee; right of action; notice to obligee; intervention by interested parties; pro rata distribution.| Any person entitled to the protection of a bond or other form of guarantee approved by a public entity under W.S. 16-6-112 may maintain an action for the amount due him. He shall notify the obligee named in the bond or other guarantee of the beginning of the action, giving the names of the parties, describing the guarantee and stating the amount and nature of his claim. No judgment shall be entered in the action within thirty (30) days after the giving of the notice. The obligee or any person having a cause of action may on his motion, be admitted as a party to the action. The court shall determine the rights of all parties to the action. If the amount realized on the bond or other guarantee is insufficient to discharge all claims in full, the amount shall be distributed among the parties pro rata.
WY Stat § 16-6-114 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-114 - Contractor's Performance and Payment Bond or Other Guarantee; Requiring New or Additional Bond or Other Guarantee; Failure to Furnish.

16-6-114. Contractor's performance and payment bond or other guarantee; requiring new or additional bond or other guarantee; failure to furnish.| If in its judgment any of the sureties on a bond or other form of guarantee approved by the public entity under W.S. 16-6-112 are insolvent or for any cause are no longer proper or sufficient sureties, the obligee may within ten (10) days require the contractor to furnish a new or additional bond or other approved guarantee. If ordered by the obligee, all work on the contract shall cease until a new or additional bond or other guarantee is furnished. If the guarantee is not furnished within ten (10) days, the obligee may at its option terminate the contract and complete the contract as the agent and at the expense of the contractor and his sureties.
WY Stat § 16-6-115 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-115 - Contractor's Performance and Payment Bond or Other Guarantee; Limitation of Actions.

16-6-115. Contractor's performance and payment bond or other guarantee; limitation of actions.| No action shall be maintained on any bond or other form of guarantee satisfactory to the public entity under W.S. 16-6-112 unless commenced within one (1) year after the date of final completion of the public work as provided in W.S. 16-6-116(a)(iv).
WY Stat § 16-6-116 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-116 - Payment to Contractor; Substantial Completion; Final Completion; Required Notices.

16-6-116. Payment to contractor; substantial completion; final completion; required notices.| (a) When any public work is let by contract, the public entity under whose direction or supervision the work is being carried on and conducted shall:  (i) Issue a certificate of substantial completion after determination that the public work, or designated portion thereof the public entity agrees to accept separately, is substantially complete;  (ii) Upon issuance of a certificate of substantial completion, cause notice to be published in a newspaper of general circulation, published nearest the point at which the work is being carried on, once a week for two (2) consecutive weeks, and posted on the state procurement website or the public entity's official website. The notice shall set forth in substance that the public entity has accepted the work, or designated portion thereof, as substantially complete according to the contract and associated documents and that the general contractor is entitled to payment as provided in paragraph (iii) of this subsection upon the forty-first day (and the notice shall specify the exact date) after the notice was first published and posted. If the contract provides for multiple substantial completions, this paragraph shall apply to each substantial completion designated in the contract;  (iii) Upon the forty-first day after the notice required under paragraph (ii) of this subsection was first published and posted, the public entity under whose direction or supervision the work has been carried on shall pay to the general contractor any payment retained by the public entity under W.S. 16-6-702(b) together with any other amount due under the contract, less any amount withheld for the portion of the public work that is incomplete or not completed in accordance with the contract and associated documents;  (iv) Issue a certificate of final completion after determination that the contract is fully performed and all portions of the public work are acceptable under the contract and associated documents. Any amounts withheld under paragraph (iii) of this subsection for the portion of the public work that was determined incomplete or not in accordance with the contract and associated documents and due under the contract shall be paid to the general contractor. The public entity shall post the date of final completion for the public work on the state procurement website or the public entity's official website.  (b) This section does not relieve the general contractor and the sureties on his bond from any claims for work or labor done or materials or supplies furnished in the execution of the contract.  (c) The public entity shall provide written notice of the requirements of this section in the project specifications.
WY Stat § 16-6-117 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-117 - Payment to Contractor; Prerequisite Filing of Contractor's Statement of Payment; Disputed Claims.

16-6-117. Payment to contractor; prerequisite filing of contractor's statement of payment; disputed claims.| In all contracts entered into by any person with a public entity for a public work, no payments under W.S. 16-6-116(a) shall be made until the person files with the public entity with which the contract has been made, a sworn statement setting forth that all claims for material, supplies and labor performed under the contract have been and are paid for the entire period of time for which the payment is to be made. If any claim for material, supplies or labor is disputed the sworn statement shall so state, and the amount claimed to be due the subcontractor or materialmen may be filed by the claimant as a claim against the general contractor's surety bond. Payment to the general contractor under W.S. 16-6-116(a) shall be paid without regard to any pending claims against the general contractor's surety bond unless the public entity has actual knowledge that the surety bond is deficient to settle known present claims, in which case an amount equal to the disputed claims may be withheld.
WY Stat § 16-6-118 (2021)
2021 Wyoming Statutes|Title 16 - City, County, State and Local Powers|Chapter 6 - Public Property|Article 1 - Public Works and Contracts|Section 16-6-118 - Unlawful Interest of Officeholders in Public Contracts or Works; Exception.

16-6-118. Unlawful interest of officeholders in public contracts or works; exception.| (a) It is unlawful for any person, now or hereafter holding any office, either by election or appointment, under the constitution or laws of this state, to become in any manner interested, either directly or indirectly, in his own name or in the name of any other person or corporation, in any contract, or the performance of any work in the making or letting of which the officer may be called upon to act or vote. It is unlawful for any officer to represent, either as agent or otherwise, any person, company or corporation, in respect of any application or bid for any contract or work in regard to which the officer may be called upon to vote or to take or receive, or offer to take or receive, either directly or indirectly, any money or other thing of value, as a gift or bribe, or means of influencing his vote or action in his official character. Any contracts made and procured in violation of this subsection are null and void and the person violating this subsection may be removed from office.  (b) Notwithstanding subsection (a) of this section, an act shall not be unlawful under this section if any person who is interested in any public contract or who represents any person, company or corporation interested in any public contract discloses the nature and extent thereof to all the contracting parties concerned therewith, absents himself during the considerations and vote thereon, does not attempt to influence any of the contracting parties and does not act directly or indirectly for the public entity in the inspection, operation, administration or performance of any contract. This section does not apply to the operation, administration, inspection or performance of banking and deposit contracts and relationships after the selection of a depository.