Case Name: SMITH, Trustee v. FIRST NAT. BANK OF CHANDLER
Court: Oklahoma Supreme Court
Jurisdiction: Oklahoma
Decision Date: 1926-05-18
Citations: 114 Okla. 293
Docket Number: No. 12473
Parties: SMITH, Trustee v. FIRST NAT. BANK OF CHANDLER.
Judges: NICHOLSON, O. J., .BRANSON, V. C. J., and PHELPS, LESTER, and RILEY, J J., concur.
Reporter: Oklahoma Reports
Volume: 114
Pages: 293–296

Head Matter:
SMITH, Trustee v. FIRST NAT. BANK OF CHANDLER.
No. 12473
Opinion Filed May 18, 1926.
Homer N. Boardman, for -plaintiff in error.
Kittenhouse & Rittenh-o-use and F. E. Lee, fet defendant in error.

Opinion:
MASON, J.
The defendant in error, First National Bank of Chandler, Okla., instituted this action against the Western Bank Supply Company, a corporation, to recover damages for the breach of a written contract, and pending the appeal the plaintiff in error, defendant beloKv, was adjudged bankrupt and A. L. Smith was appointed trustee and this action was revived in his name. The parties will be referred to- herein as they appeared in the trial court:
By the terms of said contract, which was entered into between the parties hereto on July 11, 1919, the defendant agreed to manufacture, furnish, deliver, and install certain bank fixtures in the banking house of the defendant in error, at Chandler, Okla.
The contract provided, in substance, as f-ollciws: First. That said fixtures were to be manufactured and installed according to plans and specifications which were attached to said contract. Second. The same to be completed within 70 days from acceptance of the contract by the defendant. Third. For a .consideration of $3,075, which was to be paid when the contract was. performed by t-he defendant. Fourth. The defendant was- to be relieved of delay growing out of strikes or unavoidable conditions, and have additional time equal toi the number of days lc-st. Fifth. The plaintiff should furnish free of charge ample storage space for the fixtures used in the cctaiple-tion of the contract-, either in the banking house or a warehouse convenient to the place of construction. Sixth. The contract was approved and accepted on July 11, 1919.
The fixtures were not installed by the defendant due to a fire which destroyed them on March 1. 1920, while stored pending installation, and on August 24. 1920, this action was commenced by the plaintiff to re-cover $2,917.70, as damages for. breach of said contract.
The plaintiff -alleged the execution of the contract and a subsequent agreement extending t-he time for installation of the fixtures until the spring of 1920, and also alleged a payment on the contract of $2,000, on December 15, 1919; and further alleged that defendant failed, neglected, and refused to carry ctat said contract and that t-he de-tendant advised the plaintiff, on March 23, 1920, that by reason of the increased cost of materials it had discontinued its fixture department.. Plaintiff then alleged that it was required to and did enter into a contract with the Whitc-otoxb Cabinet Company for the furnishing and installation of said fixtures, and that plaintiff was damaged in the sum of $2,917.70, and prayed judgment for that amount.
The defendant answered by general denial and filed its counterclaim for $888.20, alleging that the contract of July 11, 1919, had been modified and changed from a "building and- construction contract" to a "purchase and sale contract," and attached c-cpies of correspondence upon which it relied.
Plaintiff filed its reply, after which the ease was submitted to a jury on the issues-thus joined, and at the clctee of the plaintiff's evidence the defendant interposed its de murrer thereto, which was overruled, after which the defendant rested and moved for an instructed verdict, which was also overruled. Verdict was for tihe plaintiff in the sum of $2,876.72, upcín which the court rendered judgment, and the defendant has duly perfected its appeal to this court.
For reversal, it is first contended that the trial court erred in overruling defendant's demurrer and in refusing to instruct a verdict in its favor. In support of this 'ontention, the defendant insists that under the terms of the contract the defendant was not liable for loss of fixtures while stored, caused by dampness "Or other unfavorable conditions"; it being contended that the phrase "or other unfavorable conditions" is broad enough tol cover loss by said fire. The section of the contract involved is as follows :
"The party of the first part shall not) be responsible fc\r any damages to the furniture or material furnished in this- agreement caused by dampness, or other unfavorable conditions of the building or premises in which said furniture or material is tol be installed or in which it may be stored pending installation."
It will nob be questioned, we take it, but what this clause releases the defendant from damages resulting to said fixtures caused by dampness of the building in which the fixtures wore stored pending installation But what is the meaning of the phrase "or other unfavorable conditions"? This phrase, standing alone, is broad enough to cover any Condition that might result in damage or loss to said .fixtures. If the phrase were given the meaning it would carry when standing alone, the defendant wduld be correct in its contention, but we cannot consider it as standing alone, but must consider its sc-ope and meaning in the light of the preceding particular phrase. By the application off the rule of "ejusdem generis," in construing the meaning of general words following words of particular description, the general words are limited in meaning to the scope of the meaning of the particular words. By this rule, the phrase "or other unfavorable conditions" dotes not include a loss by fire, but it is limited in its meaning to damage resulting to said fixtures by dampness or kindred cause. Hoffman v. Eastern Wis. Ry. & L'ght Co. (Wis.) 115 N. W. 383: Board of Commissioners of Kingfisher County v. Grimes, 75 Okla. 219 182 Pac. 897; Wolf v. Blackwell O'l & Gas Co., 77 Okla. 81. 186 Pac. 484; Hickman et al. v. Cabot, 183 Fed. 747; Board of Commerce of Ann Arbor. Mich., v. Security Trust Co, 225 Fed. 454; Hawkins v. G. W. Ry. Co., 17 Mich. 56; American Bridge Company of N. Y. v. Glenmore Co. (Ky.) 107 S. W. 279; Krulewitch v. National Imp. & Trad. Co., 186 N. Y. Supp. 838; Standard Ice Co. v. Lynchburg Diamond Ice Factory Co. (Ara.) 106 S. E. 390.
This conclusion is supported by the contract, which appears in the case-made herein. Section 8 of the contract, as originally drafted, requires the First National Bank toi insure the fixtures against fire, but this section appears to have been stricken oat by having a pen drawn through it before the parties signed the contract.
Counsel for defendant, next contend that the original o contract was modified by the subsequent acts and correspondence of the parties so as to change it from a "building and construction contract" tol a "purchase .and sale contract."
It appears that the installation of the fixtures was delayed from time to time by strikes and conditions covered by the contract until the busy banking season of the fall, when they were ready to be shipped to Chandler, but, owing to the rush of business in the bank, the parties agreed to postpone the installation until spring, the bank agreeing to pay $2,000 of the consideration when (he fixtures reached Chandler, and to store them free of change. It alsoi appears that when the fixtures, which were being manufactured by another for the- defendant company, were ready to be shipped, the defendant wrote the bank and suggested that they be shipped direct to the bank at Chandler, in order to save making a second shipment from the defendant's place of business in Oklahoma City. The fixtures were subsequently shipped to the bank, at Chandler, and stored by it in the place where they were destroyed by fire. The bank also paid $2,000 of the cctasiderat-ion.
The defendant contends that these wefts were sufficient to modify the contract so as to create a purchase and sale contract, and that the title to said fixtures passed to the plaintiff: when it received them and paid the $2.000 co the consideration.
AAto see no merit in such contention, for the reason that section 7 of the original contract made it. the duty of the plaintiff to furnish the defendant, free of cost, storage for the fixtures pending their installation. It is true that by said correspondence the time of installation of1 (-he fixtures was extended until the spring of 1920-, and the time and manner of payment as set forth in the contract were changed, but such changes did not change or modify the general nature of the contract by which the defendant agreed to manufacture, furnish, and install said fixtures in the plaintiff bank. The general terms and nature of the contract remained the same though the time of its completion was passed to a future date and the plaintiff advanced a part of the contract price.
It is a fundamental r.ile in the interpretation. of contracts that where a contract is in writing and its terms and conditions are «lear and unambiguous, the intent of the •parties must be determined from the writingas a whole, and extrinsic evidence is not admissible to vary, niter, change, or modi-, fy it.
The contract under consideration falls within the above rule, and the construction thereof was a question, of law to be determined by the court. Rider v. Morgan, 31 Okla. 98, 119 Pac. 958.
In our opinion it was clearly a building and construction contract and its general nature was not modified by the change in the time cf performance and the manner of pas'ment. Therefore, the failure of the defendant to perform its part thereof rendered it liable in damages to the plaintiff. We are of .the opinion that the trial court prclperly overruled the defendant's demurrer to the plaintiff's evidence and its motion for an instructed verdict.
Ib is next urged that the trial court-erred in defining the measure of damages.
In Eckes v. Lude et al., 70 Okla. 67, 173 Pac. 219, this court, in considering the measure of damages in a case almost indentical •to the one at bar,, held:
"A building contractor who entered into a contract with the owner boi furnish material and labor and to remove the old and build in a new front in a storeroom according to plans and specifications and was to receive therefor the sum, of $725, and after certain materials had been furnished and part of the labdr performed on the contract, the contractor abandoned the work, the owner accepted the work done and materials furnished', completed the work at his dwn expense. Held, the 'contractor is - entitled to recover for the work done and materials furnished according td the contract price, in proportion that the same bears to tbe completed work, less the damages sustained by the owner by reason of the- cofatractor's failure to complete the work."
The instruction defining the measure of damages in the instant case is in complete accord with the rule abo've announced.
Finding no reversible error, the judgment of the trial court is affirmed.
NICHOLSON, O. J., .BRANSON, V. C. J., and PHELPS, LESTER, and RILEY, J J., concur.