Case Name: YACHT WEST, LTD., a Cayman Islands company, Plaintiff-Appellee, v. CHRISTENSEN SHIPYARDS, LTD., a Washington corporation; David H. Christensen, Defendants-Appellants; Yacht West, Ltd., a Cayman Islands company, Plaintiff-Appellant, v. Christensen Shipyards, Ltd., a Washington corporation; David H. Christensen, Defendants-Appellees
Court: United States Court of Appeals for the Ninth Circuit
Jurisdiction: United States
Decision Date: 2011-12-29
Citations: 464 F. App'x 626
Docket Number: Nos. 10-35382, 10-35383
Parties: YACHT WEST, LTD., a Cayman Islands company, Plaintiff-Appellee, v. CHRISTENSEN SHIPYARDS, LTD., a Washington corporation; David H. Christensen, Defendants-Appellants. Yacht West, Ltd., a Cayman Islands company, Plaintiff-Appellant, v. Christensen Shipyards, Ltd., a Washington corporation; David H. Christensen, Defendants-Appellees.
Judges: 
Reporter: West's Federal Appendix
Volume: 464
Pages: 626–629

Head Matter:
YACHT WEST, LTD., a Cayman Islands company, Plaintiff-Appellee, v. CHRISTENSEN SHIPYARDS, LTD., a Washington corporation; David H. Christensen, Defendants-Appellants. Yacht West, Ltd., a Cayman Islands company, Plaintiff-Appellant, v. Christensen Shipyards, Ltd., a Washington corporation; David H. Christensen, Defendants-Appellees.
Nos. 10-35382, 10-35383.
United States Court of Appeals, Ninth Circuit.
Argued and Submitted Nov. 14, 2011.
Filed Dec. 29, 2011.
James Douglas Baldridge, Danielle R. Foley, Venable LLP, Washington, DC, Per Arnold Ramfjord, Stoel Rives LLP, Portland, OR, for Plaintiff-Appellee.
William J. Ohle, Esquire, James M. Finn, Esquire, Michael T. Garone, Noah Jarrett, Daniel F. Knox, Esquire, Sara Kobak, Esquire, Schwabe, Williamson & Wyatt, Portland, OR, for Defendants-Appellees.
Before: FISHER, PAEZ, and CLIFTON, Circuit Judges.

Opinion:
MEMORANDUM
We consider here the cross-appeals by Christensen Shipyards, Ltd. and Yacht West, Ltd. from the district court's post-trial order granting in part and denying in part the parties' motions for judgment as a matter of law under Federal Rule of Civil Procedure 50(b). We have jurisdiction under 28 U.S.C. § 1291, and affirm.
I. Christensen's Rule 50(b) Motion
A jury's verdict of compensatory damages is reviewed for substantial evidence. In re Exxon Valdez, 270 F.3d 1215, 1247-48 (9th Cir.2001). It must be affirmed "unless the amount is grossly excessive or monstrous, clearly not supported by the evidence, or based only on speculation or guesswork." Del Monte Dunes at Monterey, Ltd. v. City of Monterey, 95 F.3d 1422, 1435 (9th Cir.1996). In calculating damages, a factfinder is entitled to "make a reasonable inference of damages from the facts adduced." Holland Livestock Ranch v. United States, 655 F.2d 1002, 1006 (9th Cir.1981).
1. Substantial evidence supported the jury's award of $2.6 million to Yacht West for the nonconforming exhaust system. Yacht West's expert testified that his conceptual analysis showed that it was possible to reroute the exhaust system to discharge at the rear of the boat for $2.6 million, and that a variety of specific implementations of his general concept were feasible.
2. Substantial evidence did not support the jury's award of $2 million to Yacht West for a structural defect in the form of either a vibration or weight in excess of the contract requirements. A Yacht West expert opined that the vibration was "hull-springing vibration" caused by a "lack of stiffness in the structure," but admitted that he could not tell the juiy how the problem could be corrected because "it requires further testing." Another Yacht West expert testified that it would cost $4 million "to repair the structural inadequacy of the vessel," but that it would first entail "a very substantial effort . to find out why the boat is vibrating the way that it is."
Because neither Yacht West expert could identify the source of the vibration or specify how to fix it, the jury was required to impermissibly speculate about the provenance and redressability of the vibration. The district court therefore correctly granted Christensen's Rule 50(b) motion on this issue.
II. Yacht West's Rule 50(b)Motion
I. Substantial evidence supported the jury's award of $1,674,242 to Christensen for delay damages not stemming from unabsorbed overhead. Interpretation of an integrated agreement "is to be determined by the trier of fact if it depends on . a choice among reasonable inferences to be drawn from extrinsic evidence." Berg v. Hudesman, 115 Wash.2d 657, 801 P.2d 222, 229 (1990) (quoting Restatement (Second) of Contracts § 212 (1981)) (internal quotation marks omitted). The parties presented testimony to the jury about the meaning of the contract. The jury received a general instruction and special verdict form, and neither party objected that the jury instructions or special verdict were improper. Further, Christensen's expert testified that Yacht West and its contractors and suppliers delayed construction by failing to provide necessary information and materials, and that these delays subsumed any delays caused by Christensen. Substantial evidence supported the jury's finding that the contract permitted an award for delay damages and the amount of delay damages it awarded.
2. "The raison d'etre of Eichleay requires at least some element of uncertainty arising from suspension, disruption or delay of contract performance. Such delays are sudden, sporadic and of uncertain duration. As a result, it is impractical for the contractor to take on other work during these delays." C.B.C. Enters, v. United States, 978 F.2d 669, 675 (Fed.Cir. 1992). In Washington, unabsorbed overhead is recoverable "if the delay prevented the contractor from obtaining contracts during the delay period that would have 'absorbed' the ongoing overhead expense." Golf Landscaping, Inc. v. Century Constr. Co., 39 Wash.App. 895, 696 P.2d 590, 593 (Wash.Ct.App.1984). Christensen's workforce was never placed on standby during the construction of the Party Girl, and there is no evidence that the delays prevented Christensen from taking on new contracts. Christensen is therefore precluded from obtaining damages for unabsorbed overhead.
AFFIRMED.
This disposition is not appropriate for publication and is not precedent except as provided by 9th Cir. R. 36-3.