In this task, you're given a passage that represents a legal contract or clause between multiple parties. Your job is to write questions that ask the basic details corresponding to the legal contracts or clauses. Avoid questions that can be answered correctly without actually understanding the paragraph, and which might have multiple answers. The answer to each question should be unambiguous.

Exhibit 10.5 Confidential Treatment Requested by Achaogen, Inc.   COLLABORATIVE DEVELOPMENT AND COMMERCIALIZATION AGREEMENT

  This Collaborative Development and Commercialization Agreement (Agreement) is entered into as of April 26, 2016 (Effective Date) by and between Microgenics Corporation (hereinafter Microgenics), having its principal place of business at 46500 Kato Road, Fremont, California 94538, and Achaogen Inc. (hereinafter Achaogen), having a place of business at 7000 Shoreline Court, #371, South San Francisco, California 94080. Both Microgenics and Achaogen are referred to herein individually as a Party and collectively as the Parties.   WHEREAS, Achaogen possesses certain intellectual property rights and know-how relating to drug compound Plazomicin;   WHEREAS, Microgenics has certain expertise and know-how relating to the development, manufacture and sale of immunoassays for in vitro diagnostic use;   WHEREAS, the Parties are undertaking, as of the Effective Date, activities under that certain Antibody Development Agreement, dated [***] (the Antibody Development Agreement), for the purpose of identifying and developing antibodies against Plazomicin and this Agreement is the Assay Commercialization Agreement referred to in Section 2.6 of the Antibody Development Agreement; and   WHEREAS, the Parties desire to collaborate on the development and commercialization of a therapeutic drug monitoring assay for the measurement of concentrations of Plazomicin in biological fluids.   NOW THEREFORE, in consideration of the foregoing premises and the covenants and promises contained herein, the Parties intending to be bound, hereby agree as follows:   1. Definitions   For the purposes of this Agreement and the Exhibits hereto, the following words and phrases shall have the following meanings (words defined in the Agreement shall have the meaning ascribed to them in that Section):   1.1 Achaogen Know-How shall mean all proprietary, technical and clinical information, data and know-how relating to Plazomicin and haptens and polyclonal antibodies related directly to Plazomicin, whether or not patentable, which is Controlled as of the Effective Date or acquired during the Term by Achaogen.   1.2 Achaogen Materials shall mean the materials set forth in Exhibit A.   1.3 Achaogen Patents shall mean the Patents and Patent applications set forth in Exhibit B hereto.   1.4 Affiliate shall mean, with respect to a Party, any corporation, or other business entity which directly controls, is controlled by or is under common control with that Party. A person or entity shall be regarded as in control of another entity if it owns, directly or indirectly, fifty percent (50%) or more of the outstanding equity securities of the subject entity which is entitled to vote in the election of directors, or a fifty percent (50%) or greater interest in the net assets or profits of the subject entity if such entity is not a corporation.

[***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     1.5 Applicable Law shall mean all applicable provisions of all statutes, laws, rules, regulations, administrative codes, ordinances, decrees, orders, decisions, injunctions, awards judgments, permits and licenses of or from governmental authorities, including those relating to or governing the use or regulation of the subject item and the listing standards or agreements of any national or international securities exchange.   1.6 Assay shall mean an antibody-based immunoassay or immunoassays used for the  in vitro measurement of Plazomicin concentration in human blood and other body fluids,  [***], that (a) uses or otherwise would infringe Immunoassay Technologies, (b) is developed by Microgenics and its Affiliates under this Agreement, and (c) [***].   1.7 Commercially Reasonable Efforts shall mean efforts and resources normally utilized by a Party for a product owned by it or to which it has rights, which is of similar market potential at a similar stage in its product life, taking into account the competitiveness of the marketplace, the proprietary position of the product, the regulatory structure involved, the profitability of the applicable products, the relative benefit that accrues to actual and potential patients and other relevant factors; provided, that, in any event, Commercially Reasonable Efforts under this Agreement require that a Party (a) [***], (b) [***], and (c) [***].   1.8 Confidential Information shall mean all proprietary and confidential business, technical, scientific, and/or regulatory information relating to the Assay, Plazomicin, and/or the purpose of, or activities under, this Agreement, that is provided by or on behalf of a Disclosing Party to a Receiving Party hereunder, whether disclosed in writing or orally.   1.9 Control shall mean with respect to any (a) item of information, including know-how, or (b) intellectual property right, the possession (whether by ownership or license) by a Party of the ability to grant to the other Party access and/or a license as provided herein under such item or right without violating the terms of any agreement or other arrangements with any Third Party existing before or after the Effective Date.   1.10 Development and Manufacturing Phase shall mean that phase of the Research Program set forth in the Project Plan relating to the optimization of the Assay and the manufacture and validation of [***] ([***]) production lots of the Assay that meet the Specifications [***].   1.11 Feasibility Study Phase shall mean that phase of the Research Program set forth in the Project Plan comprising all studies conducted by Microgenics to establish the feasibility for developing the Assay by demonstrating (a) [***], (b) [***], (c) [***], (d) [***], (e) [***], and (f) [***].   1.12 First Commercial Sale shall mean (a) with respect to the Assay, the initial sale by or on behalf of Microgenics (or its Affiliates) of the Assay and (b) with respect to Plazomicin, the initial sale by or on behalf of Achaogen (or its Affiliates) of Plazomicin, in each case, to a Third Party in exchange for cash or some equivalent to which value can be assigned; provided, that a sale of the Assay or Plazomicin, as applicable, in connection with [***] of the Assay or Plazomicin, as applicable, or for [***] therefor will not constitute First Commercial Sale.   1.13 Good Clinical Practice or GCP shall mean the then current standard for clinical trials for assays, as set forth in the United States Federal Food, Drug and Cosmetics Act and applicable regulations

Page 2 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   promulgated thereunder, as amended from time to time and such standards of good clinical practice as are required by the European Union and other organizations and governmental agencies in countries where the Assay is intended to be sold, to extent such standards are no less stringent than United States GCP.   1.14 Good Laboratory Practice or GLP shall mean the then current standards for laboratory activities for assays, as set forth in the United States Federal Food, Drug and Cosmetics Act and applicable regulations promulgated thereunder, as amended from time to time and such standards of good laboratory practice as are required by the European Union and other organizations and governmental agencies in countries where the Assay is intended to be sold, to extent such standards are no less stringent than United States GLP.   1.15 Good Manufacturing Practices or GMP shall mean the then current standards for the manufacture of assays, as set forth in the United States Federal Food Drug and Cosmetics Act and applicable regulations promulgated thereunder, as may be amended from time to time and such standards of good manufacturing practice as are required by the European Union and other organizations and governmental agencies in countries where the Assay is intended to be sold, to extent such standards are no less stringent than United States GMP.   1.16 Immunoassay Technologies shall mean technologies, including any patentable or unpatentable intellectual property rights appurtenant thereto, Controlled by Microgenics or its Affiliates suitable for developing and manufacturing assays, calibrators and controls for application on  [***], including  [***] assay technology,  [***] technology,  [***] technology,  [***] immunoassay, the Microgenics Cell Line, and Microgenics [***] Antibodies.   1.17 Microgenics Cell Line shall mean those certain cell lines (a) that were developed under the Antibody Development Agreement, or (b) that produce Microgenics [***] Antibodies and are Controlled by Microgenics and listed in Exhibit C, as such Exhibit may be amended from time to time upon the mutual written agreement of the Parties.   1.18 Microgenics Know-How shall mean all proprietary, technical information, data and know-how relating to the Assay or Immunoassay Technologies and reagents for use therewith which are Controlled as of the Effective Date or acquired or developed during the Term by Microgenics or its Affiliates.   1.19 Microgenics [***] Antibodies shall mean [***] antibodies developed by, or Controlled by, Microgenics or its Affiliates and directed to Plazomicin.   1.20 Patent shall mean any existing or future: (a) national, regional or international patent or patent application in any jurisdiction (including any provisional, divisional, continuation, continuation-in-part, non-provisional, converted provisional, or continued prosecution application, any utility model, petty patent, design patent and/or certificate of invention), (b) any extension, restoration, revalidation, reissue, re-examination and extension (including any supplementary protection certificate and the like) of any of the foregoing patents or patent applications, and (c) any ex-U.S. equivalents corresponding to any of the foregoing.   1.21 Plazomicin shall mean Achaogen's aminoglycoside antibiotic that is in Phase 3 clinical development as of the Effective Date and having the chemical structure shown on Exhibit D, and [***] thereof, regardless of commercial name.

Page 3 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   1.22 Primary Countries shall mean (a) the countries set forth on  Exhibit E  and (b) any other country in the Territory which the Parties mutually agree in writing shall be a Primary Country in accordance with Section 4.2.5, in each case, for which the Parties intend to pursue initial registration, commercialization and launch of the Assay.   1.23 Project Plan shall mean the plan of work to be conducted under the Research Program pursuant to Section 2.1 (Project Plan) hereof as attached as Exhibit F.   1.24 Regulatory  Approval shall mean all authorizations, registrations or clearances with or by the appropriate Regulatory Authorities which are required for the marketing, promotion, pricing and sale of either the Assay or Plazomicin, as applicable, in any country or regulatory jurisdiction in the Territory.   1.25 Regulatory Authority shall mean any national, supra-national, regional, state or local regulatory agency, department, bureau, commission, council or other governmental entity involved in the granting of Regulatory Approval, including the United States Food and Drug Administration.   1.26 Research Program shall mean the collaborative program of research relating to the development of the Assay to be carried out by the Parties pursuant to this Agreement.   1.27 Secondary Countries shall mean all countries in the Territory, other than the Primary Countries.   1.28 Shortfall License shall mean a temporary, fully-paid up, royalty-free, worldwide non-exclusive license granted by Microgenics (including on behalf of its Affiliates as appropriate), under Section 4.3.2.3, to (a) the Immunoassay Technologies and (b) all other intellectual property rights (including Patent applications, Patents, trade secrets, copyrights, and trademarks) (i) of Microgenics (or its Affiliates as appropriate) arising out of the performance of this Agreement or the Antibody Development Agreement, or (ii) Controlled by Microgenics (or its Affiliates as appropriate) that are necessary or desirable for or used in the manufacture and commercialization of the Assay, which license would be for the manufacture, use, sale, offer for sale and import of the Assay. Such license shall be fully sub-licensable to any Third Party for purposes of manufacturing and commercializing the Assay (including the components thereof) under Section 4.3.2.3.   1.29 Specifications shall mean the specifications applicable to the Assay, as set forth on Exhibit G.   1.30 Territory shall mean the world.   1.31 Third Party(ies) shall mean any person(s) or entity(ies) other than Achaogen, Microgenics or their respective Affiliates.   1.32 Trademarks shall mean all registered and unregistered trademarks (including all common law rights thereto), service marks, trade names, brand names, logos, taglines, slogans, certification marks, Internet domain names, trade dress, corporate names, business names and other indicia of origin, together with the goodwill associated with any of the foregoing and all applications, registrations, extensions and renewals thereof throughout the world, and all rights therein provided by international treaties and conventions.

Page 4 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   1.33 Transfer License shall mean a royalty-bearing, worldwide exclusive license granted by Microgenics (including on behalf of its Affiliates as appropriate), under Section 9.4.4.1, to (a) the Immunoassay Technologies and (b) all Patent applications, Patents, trade secrets and other know-how, (i) of Microgenics (or its Affiliates as appropriate) arising out of the performance of this Agreement or the Antibody Development Agreement, or (ii) Controlled by Microgenics (or its Affiliates as appropriate) as of the termination date of this Agreement that are necessary for or used in the development, manufacture, and commercialization of the Assay, which license would be solely for the development, manufacture, use, sale, offer for sale and import of the Assay in connection solely with the use of Plazomicin. Such license shall be fully sub-licensable to any Third Party for purposes of manufacturing and commercializing the Assay (including the components thereof) [***].   1.34 Additional Definitions. Each of the following definitions is set forth in the Section of the Agreement indicated below.   Definition Section AAA 13.8.2 Abandoned Commercialization 4.2.7.1 Abandoned Development 4.2.7.1 Achaogen Preamble Achaogen Indemnified Parties 11.2 Achaogen Inventions 8.1 Agreement Preamble Alliance Manager 5.1.1 Antibody Development Agreement Recitals Assay Commercialization Plan 4.2.4 Audit Outcome 4.4.2 Back-up Supplier 4.3.2.2 Binding Forecast 4.2.2 Commercial Leader 5.3.1 Convicted Entity or Convicted Individual 10.4.4 Debarred Entity 10.4.2 Debarred Individual 10.4.1 Development Leader 5.3.1 Disclosing Party 12.1 Dispute 13.8.1 Effective Date Preamble Excluded Entity or Excluded Individual 10.4.3 FDA 10.4.5 FDA Disqualified/Restricted List 10.4.5 Force Majeure Event 13.1 Functional Leaders 5.3.1 Joint Project Team or JPT 5.3.1 JSC 5.2 [***] Products 8.1 Joint Patent 8.2.2 Launch Plan 4.2.4 Losses 11.1

Page 5 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Definition Section Microgenics Preamble Microgenics Indemnified Parties 11.1 Microgenics Inventions 8.1 Minimum Threshold 4.2.3 Minimum Threshold Period 4.2.3 Party or Parties Preamble Plazomicin Commercialization Plan 4.2.1 Receiving Party 12.1 Regulatory Finding 3.3.1.2 Regulatory Leader 5.3.1 Responsible Party 8.3.1 Review Party 8.3.1 Supply Resumption Date 4.3.2.2 Term 9.1 Third Party Claims 11.1 VAT 7.3.2     2 Research and Development Collaboration   2.1 Project Plan. The Parties shall collaborate on the Research Program in accordance with the Project Plan, as set forth as Exhibit F. As may be necessary or reasonable from time-to-time, the JPT may suggest appropriate revisions to the Project Plan to the JSC for its review in accordance with Section 5.3.2 and, if approved by the JSC in accordance with Section 5.1, the Project Plan may be amended from time to time by the JSC.   2.2 Party Responsibilities.   2.2.1 General. Microgenics and Achaogen shall each perform their respective obligations under the Research Program, using Commercially Reasonable Efforts, in accordance with the Project Plan and in compliance with Applicable Law.   2.2.2 Achaogen. Achaogen shall supply to Microgenics,  [***], (a) Achaogen Materials, including Plazomicin and Plazomicin clinical patient samples, in such quantities as are set forth in Exhibit A or otherwise mutually agreed by the Parties or set forth in the Project Plan; and (b) all necessary and in Achaogen's possession Plazomicin pharmacological and biochemical information, including  [***] etc., to enable the JPT to correctly design the Assay and Microgenics to work with the appropriate Regulatory Authorities to secure Regulatory Approval for the Assay. Microgenics shall not transfer any portion of the Achaogen Materials to any Third Party or use the Achaogen Materials for any purpose other than the purposes of performing its obligations under, and in accordance with, this Agreement and the applicable Project Plan. Microgenics shall hold, store and transport all supplies of the Achaogen Materials in compliance with all Applicable Laws and  [***]. Microgenics shall maintain complete and accurate records relating to the disposition of all Achaogen Materials.   2.2.3 Microgenics. Subject to the provisions of this Agreement (including Article 3 (Regulatory Submissions and Meetings)), Microgenics shall be responsible for the research, development, manufacture and sale of the Assay. Microgenics shall manufacture the Assay according to the Specifications

Page 6 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   attached hereto as  Exhibit G (which may be amended from time to  time by the JSC in accordance with Section  5.1) and in accordance with the timelines set forth in the Project Plan. Without limiting the foregoing, Microgenics shall develop and commercialize the Assay such that it is capable of being run on no less than [***] ([***]) distinct [***] platforms, which [***] platforms shall be mutually agreed upon by the Parties in good faith.   2.3 Information Exchange, Records and Compliance.   2.3.1 Technology Transfer.  Achaogen shall provide Microgenics with all Achaogen Know-How  [***] reasonably necessary for Microgenics to carry out its responsibilities under the Research Program and to obtain Regulatory Approvals for the Assay. Microgenics shall provide Achaogen with all Microgenics Know-How  [***] reasonably necessary for Achaogen to carry out its responsibilities under the Research Program and to conduct clinical trials of Plazomicin. All information exchanged shall be subject to the confidentiality requirements set forth in Article 12 (Confidentiality) hereof.   2.3.2 Record Keeping/Compliance. During the Term and for a period of [***] ([***]) years thereafter (or such longer period of time as required by Applicable Laws), each Party shall maintain records in sufficient detail and in good scientific manner appropriate for obtaining and maintaining Regulatory Approvals. Achaogen shall have the right (either by itself or through a Third Party reasonably acceptable to Microgenics), during normal business hours and upon reasonable notice, to inspect records pertinent to Microgenics' obligations under this Agreement. To the extent such records contain Confidential Information of Microgenics, Achaogen shall maintain such Confidential Information disclosed therein in confidence in accordance with Article 12. Achaogen shall have the right to arrange for its employee(s) and/or consultant(s) involved in the activities contemplated hereunder, during normal business hours and upon reasonable notice, to discuss the development activities and results contemplated under this Agreement in detail with the technical personnel and consultant(s) of Microgenics. Each Party shall comply with all applicable GLP, GCP, GMP, ISO 9001 and ISO 13485:2003 requirements and other Applicable Laws in the conduct of the Research Program and in the activities contemplated under this Agreement, including the development, manufacture and commercialization of the Assay.   2.4 Installation and Training. Upon Achaogen's request, Microgenics shall, [***], install any necessary equipment and train appropriate staff at clinical sites designated by Achaogen for the performance of clinical trials by Achaogen, in connection with obtaining Regulatory Approval for Plazomicin, and in order to enable such sites to use the Assay in connection with such use of Plazomicin and provide training for such sites' personnel on how to operate such equipment. For clarity, [***] shall be [***] responsible for the costs of (a) any clinical trials conducted for purposes of obtaining Regulatory Approval for the Assay (as opposed to Regulatory Approval for Plazomicin) and (b) any activities conducted in a given country in the Territory following the receipt of Regulatory Approval for the Assay for such country (e.g. commercial activities).   2.5 Quality Agreement. No later than  [***]  ([***]) days after the Effective Date (or such later date as may be otherwise agreed upon by the Parties in writing), the Parties shall enter into a quality agreement defining the commitments of both Parties to ensure that the Assay and related services developed and commercialized under this Agreement satisfy the quality and regulatory requirements required by this Agreement.  Microgenics shall manage all Achaogen Materials (including clinical patient samples) according to customer property requirements described in such quality agreement.   2.6 BARDA Requirements. The Parties acknowledge and agree that Achaogen receives funding

Page 7 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   from the United States government through the Biomedical Advanced Research and Development Authority within the office of the Assistance Secretary for Preparedness and Response in the United States Department of Health and Human Services (BARDA) in connection with Achaogen's development of new antibacterial treatment of MDR gram-negative bacterial infection. In connection with the foregoing, the terms and conditions of this Agreement shall be subject in their entirety to the terms and conditions set forth on Appendix A of Exhibit H. In the event of any conflict between the terms and conditions of the main body of this Agreement and Appendix A of Exhibit H, Appendix A of Exhibit H shall control.   3 Regulatory Submissions and Meetings    3.1 Coordination. Achaogen and Microgenics shall [***] coordinate the therapeutic and diagnostic regulatory filings and communications with Regulatory Authorities in the Territory. Achaogen will be responsible for all activities regarding the Regulatory Approval of Plazomicin (and, as between the Parties, Achaogen shall retain ownership of all regulatory filings and Regulatory Approvals for Plazomicin), and, subject to the terms and conditions of this Agreement,  [***] will be responsible for all activities regarding the Regulatory Approval of [***] (and, as between the Parties, [***] shall retain ownership of all regulatory filings and Regulatory Approvals for [***]). For the avoidance of doubt, the Parties acknowledge and agree that, notwithstanding anything herein to the contrary, but subject to Section 3.2 and Section 4.2.7, (a) Achaogen shall have the sole discretion, at any time during the Term, to determine whether to conduct any clinical trial or make any regulatory filing, submission or correspondence with respect to Plazomicin; and (b) [***], subject to Section 4.2.7, at any time during the Term, to conduct any clinical trial (provided, that, in the event of a clinical trial that involves the use or administration of [***], [***]) or make any regulatory filing, submission or correspondence with respect to [***].   3.2 Reporting and Consultation. [***] shall keep [***] regularly informed in connection with the preparation of all regulatory filings, submissions or correspondence related to  [***] and  [***] shall have the right to review and comment on any regulatory filing, submission or correspondence related to [***] (including any [***]), to be submitted to any health authority by [***]. In connection therewith, [***] shall provide to [***] for review the text of any such regulatory filing, submission or correspondence for [***] prior to submission and  [***] shall consider in good faith all comments provided by  [***]; provided that any disputes with respect to comments provided by [***] shall be resolved by the JSC. In addition, [***] shall consult with [***] with respect to all material matters required for regulatory filings, submissions or correspondence, under this Agreement; provided, however, that, subject to Section 3.1,  [***] shall have sole responsibility hereunder for all regulatory filings (including  [***] or their ex-United States equivalent), submissions or correspondence, including preparing and analyzing all  [***] information required pursuant to any and all Applicable Laws, and preparing and analyzing any additional data and information required by any applicable Regulatory Authority (other than any data or information regarding [***]). Upon written request from [***], [***] shall promptly provide to [***] copies of all submitted regulatory filings, submissions, and material correspondence to and from any Regulatory Authorities; provided, that [***] may redact from such copies information that does not relate to the Assay, Plazomicin or this Agreement and the activities hereunder.   3.3 Correspondence from Regulatory Authority.   3.3.1.1 If either Party receives any material communication from the Regulatory Authorities relating to  [***] or has any meetings (telephonic or in person) with any Regulatory Authority for any material reason regarding [***], such Party shall promptly notify the other Party and, upon mutual agreement, decide whether it is necessary for the other Party to be present in any

Page 8 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   discussions with the Regulatory Authorities regarding  [***]; provided,  however, that, notwithstanding the foregoing, Achaogen shall have the right to participate in (a)  [***], (b)  [***], or (c)  [***] pertaining to Achaogen Materials or Achaogen Know-How. For clarity, as between the Parties,  [***] shall be responsible for leading any meetings or other discussions with the  [***].  [***]  shall not make any representations or discuss the uses of  [***] with any Regulatory Authority except to the extent it relates to [***]. Neither Party shall disclose, without the other Party's prior written consent, Confidential Information of such other Party in any regulatory filing, submission or correspondence or at a meeting with any Regulatory Authority, except to the extent required by Applicable Laws or otherwise under the Project Plan.

3.3.1.2 In addition, Microgenics shall notify Achaogen within [***] ([***]) business days of any regulatory finding or violation identified by a Regulatory Authority that may potentially impact the activities contemplated under the Project Plan or the development, manufacture or commercialization of the Assay (a Regulatory Finding). With respect to each Regulatory Finding, if any, Microgenics shall provide (1) (a)  [***], or (b)  [***], or (c)  [***] and (2) Microgenics' [***]; provided, that, in each case of clauses (a), (b), and (c), Microgenics' may redact from such copies or reports information that does not relate to the Assay, Plazomicin or this Agreement and the activities hereunder. Without limiting the next to last sentence of Section 3.5, Microgenics shall notify Achaogen promptly of any notification or information received from a Regulatory Authority, that: (i) would reasonably be expected to impair the integrity or reputation of Plazomicin or the Assay; (ii) raises any material concerns regarding the safety or efficacy of Plazomicin or the Assay; (iii) indicates or suggests a potential material liability of either Party to Third Parties in connection with Plazomicin or the Assay; (iv) is reasonably likely to lead to a recall or market withdrawal with respect to Plazomicin or the Assay; or (v) [***].

3.4 Package Insert Information.  Notwithstanding anything to the contrary contained herein, but subject to any applicable review and comment rights of the other Party, and dispute resolution escalation procedures set forth in Section 13.8, [***] shall have final decision making authority on all package insert language directed  [***], and [***] shall have final decision making authority on all Assay package insert language directed [***].   3.5 Filings.  On a country-by-country basis, a Regulatory Approval from the applicable Regulatory Authority(ies) is required for the Assay prior to launch in such country. Upon Achaogen's request, Microgenics shall reasonably cooperate with Achaogen with respect to any regulatory filings, submissions, or correspondence made by Achaogen related to Plazomicin in any country in the Territory, including promptly providing data, information and advice regarding the Assay, including the manufacture (including any recall information) and use thereof. This Agreement generally assumes that there is a current 510(k) pathway for obtaining Regulatory Approval for the Assay; provided, that, if a PMA pathway is required, the Parties acknowledge and agree that [***] reviewed by the Parties and may need to be adjusted to the extent agreed upon between the Parties and subject to the proviso in the foregoing sentence. For the avoidance of doubt, Achaogen shall have sole right to control any such regulatory filings, submissions, correspondence or other matters related to Plazomicin including any joint submissions or filings, but not [***], and to communicate with Regulatory Authorities related thereto. No later than [***] (or such later date as otherwise agreed to by the Parties), the Parties shall enter into an agreement setting forth the Parties respective responsibilities for adverse event and complaint reporting, the exchange of safety data and, to the extent agreed by the Parties to be appropriate and relevant, recall matters.   3.6 Right of Reference. [***] hereby grants to [***] a non-exclusive, non-transferable (except

Page 9 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   in connection with a permitted assignment, sublicense or subcontract) right of reference (as defined in 21 CFR 314.3(b)) with respect to clinical trial data and results related to [***], solely as necessary for [***] to prepare, submit and maintain regulatory submissions related to  [***] and Regulatory Approvals for  [***].  [***] hereby grants to  [***] a non-exclusive, non-transferable (except in connection with a permitted assignment, sublicense or subcontract) right of reference (as defined in 21 CFR 314.3(b)) with respect to [***] clinical trial data (including  [***]), information (including the  [***], as applicable) and results related to  [***], solely as necessary for [***] to prepare, submit and maintain regulatory submissions related to [***] and Regulatory Approvals for [***].    3.7 [***]. In connection with the  [***] of  [***] in any  [***] in the Territory,  [***] shall  [***] of the  [***] in [***] in [***] with such [***] of [***]. The Parties shall discuss in good faith (via the JPT) and mutually agree as to [***] shall [***] for [***], which discussion and decision shall occur no later than [***] ([***]) year [***]. In the event that the Parties later agree to [***] for [***] in a [***], the Parties (through the JPT and JSC) shall amend the Project Plan to [***], subject to [***], and [***] shall [***].   4 Manufacture and Commercialization of Assay   4.1 Manufacture. Except as provided elsewhere in this Agreement, including Section 4.3 (Supply) and Section 9.4.4 (Effect of Termination), during the Term, Microgenics shall be solely and exclusively responsible for the worldwide manufacture of the Assay in accordance with GMP standards, the Specifications and Applicable Law. For clarity, from and after the expiration or termination of this Agreement, nothing in this Agreement shall restrict Microgenics from developing, manufacturing or commercializing the Assay as and to the same extent as any third party.   4.2 Commercialization. Upon successful completion of the Development and Manufacturing Phase and upon receipt of the applicable Regulatory Approval in a given country in the Territory required in order to sell the Assay in such country, Microgenics shall use Commercially Reasonable Efforts to exclusively commercialize and market the Assay, under the Thermo Scientific tradename and packaging and utilizing Microgenics' and its Affiliate's commercial infrastructure, in each country within the Territory in which Achaogen is commercializing Plazomicin for so long as Achaogen is commercializing Plazomicin in such country. Solely to the extent Achaogen elects to promote an assay which may be capable of measuring Plazomicin in a given Primary Country ([***]) in the Territory, and subject to receipt and conditions of any applicable Regulatory Approvals, Achaogen shall prioritize the promotion of the Assay relative to any other assay which may be capable of measuring Plazomicin, in its marketing and sales efforts in such Primary Country; provided, however, that in the event (a) Microgenics [***] is unable to supply the Assay in quantities sufficient to meet each applicable Binding Forecast, including [***], or (b) [***], Achaogen may prioritize the promotion of assays capable of measuring Plazomicin in the affected country(ies). For clarity, and notwithstanding anything to the contrary in this Agreement, including this Section 4.2, Achaogen expressly reserves and retains the right to, directly or indirectly (including through contractors or collaborators), research, develop, manufacture, use or commercialize assays capable of measuring Plazomicin other than the Assay; provided, that, Achaogen may not, directly or indirectly (including through contractors or collaborators) commercialize any immunoassay [***], other than the Assay in accordance herewith, [***]; provided, further, that the restriction on Achaogen's right to commercialize immunoassays [***], other than the Assay, shall be of no force or effect if Microgenics is unable to supply the Assay for [***] ([***]) days at any time [***] or if the Parties mutually determine that Microgenics will not be able to supply the Assay. Additional commercialization and supply terms may be added to this Agreement in the form of an amendment. Without limiting the foregoing:

Page 10 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   4.2.1 Plazomicin Commercialization Plan. As soon as commercially reasonable, but no later than [***] ([***]) days after the Effective Date of this Agreement, Achaogen shall share its global commercialization plans for Plazomicin with Microgenics (Plazomicin Commercialization Plan). The Plazomicin Commercialization Plan shall include the list of  countries consistent with the Primary Country list for commercialization of Plazomicin, anticipated launch timing, initial volume forecasts and such other information as may be determined by the JPT. Microgenics will develop timelines on a country basis to the extent it receives adequate Plazomicin Commercialization Plan details with respect to a given country. Achaogen agrees to keep such Plazomicin Commercialization Plan updated via regular communication with the JSC. For clarity, (a) the Plazomicin Commercialization Plan shall be Confidential Information of Achaogen hereunder, and (b) Achaogen [***] in preparing and conducting activities under the Plazomicin Commercialization Plan.

4.2.2 Volumes and Pricing.

4.2.2.1 On a regular basis, beginning at least [***] ([***]) months prior to the anticipated date of the First Commercial Sale of Plazomicin in the Territory, Achaogen will share confidential, non-binding (except as described below) good faith volume forecasts in units for the Assay and updates thereof in the Plazomicin Commercialization Plan through the JSC in order for the Parties to develop a  [***] market introduction including achieving Regulatory Approval [***] for the Assay in all relevant countries and regions. Thereafter, and on a  [***] basis, Achaogen shall supply Microgenics with a confidential, good faith rolling  [***]  ([***]) month forecast (in units, broken-down by country (or regions)) as to Achaogen's estimated unit demand for worldwide commercial demand for the Assay (it being agreed and understood that such forecasts shall be Confidential Information of Achaogen hereunder); provided, however, only the first [***] ([***]) months of each [***] ([***]) month forecast shall be binding (a Binding Forecast) and the remaining [***] ([***]) months of such forecast shall be non-binding (for clarity, when each [***] forecast update is provided, [***] of the previous forecast (i.e., [***] of the Binding Forecast previously submitted) shall not be changed as they become [***] of the current forecast and [***] of the current Binding Forecast). For clarity, except as otherwise provided in this Agreement with respect to the Binding Forecast, Achaogen shall have no liability whatsoever with respect to such forecasts, including no liability for any Assay manufactured or materials ordered by or on behalf of Microgenics based on such forecasts. Microgenics shall supply the quantities of the Assay set forth in the applicable Binding Forecasts and shall use Commercially Reasonable Efforts to ensure that [***], in each case, in accordance with Section 4.3; provided, however, [***].

4.2.2.2 The Parties acknowledge and agree that  [***] shall have  [***] with respect to the pricing of the Assay in any country in the Territory; provided, however,  [***] shall  [***] to price the Assay in a given country at an amount no greater than (i) (a) $[***] in the United States or (b) $[***] in any other country, or (ii)  [***] percent ([***]%) of the applicable list price of any other [***] assay marketed in such country; provided, further, that [***] shall [***] to take into account [***]. In the event that (x) [***] to price the Assay at an amount greater than the foregoing subclauses (i) and (ii), then the JSC shall review the available data and discuss the Assay price in accordance with Section 5.2.1(h), and/or (y) the Assay pricing [***], the JSC will review the available data and discuss various alternative solutions.

4.2.3 Minimum Thresholds.  In the event that, during the applicable Minimum Threshold Periods (as defined below), Microgenics does not receive the applicable Minimum Threshold Revenue (as defined below) during a given calendar year, Achaogen agrees to pay  [***] Microgenics for such region during such calendar year (on a prorated basis, as applicable). For purposes of this Section 4.2.3,

Page 11 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   4.2.3.1 The First Minimum Threshold Period shall begin on the  [***]  ([***]) anniversary of the date on which the First Commercial Sale of the Assay in [***] occurred and shall end on the [***] ([***]) anniversary of the date on which the First Commercial Sale of the Assay in [***] occurred. For example, if the First Commercial Sale of the Assay in [***] occurred on [***] then the First Minimum Threshold Period would begin on [***] and would end on [***];

4.2.3.2 The Second Minimum Threshold Period shall begin on the [***] ([***]) anniversary of the earlier of the date on which the First Commercial Sale of the Assay occurred in (i) [***] of the following countries - [***] (each an [***] Country); or (ii) an  [***] Country and  [***]; or (iii)  [***]  ([***]) of the Primary Country list ([***]) (subclause (i), (ii), or (iii), as applicable, the Start Date), and shall end on the earlier of (a) the  [***]  ([***]) anniversary of the Start Date or (b) the date this Agreement expires or terminates;

4.2.3.3 Minimum Threshold Revenue shall mean, with respect to each of the First Minimum Threshold Period and the Second Minimum Threshold Period, USD $[***] of annual gross revenue received by Microgenics from sales of the Assay in the Territory (for clarity, during any overlap between the First Minimum Threshold Period and the Second Minimum Threshold Period, the total Minimum Threshold Revenue would be USD $[***]); provided, however, that the Minimum Threshold Revenue (i) shall be determined by [***] for a given Assay, less [***] directly associated with such sale and Assay and permitted to be taken in accordance with generally accepted accounting principles in the United States, and (ii) that in the event the Minimum Threshold Period begins or ends during a given calendar year, the Minimum Threshold Revenue for such calendar year shall be prorated accordingly.

4.2.4 Market Introduction. The Parties will reasonably agree regarding details related to commercialization of the Assay once the [***] are clarified by Achaogen in the Plazomicin Commercialization Plan. Within [***] ([***]) months of receiving the initial Plazomicin Commercialization Plan, Microgenics will provide Achaogen with (a) a detailed market introduction plan for the Assay (the Launch Plan) and (b) a global commercialization plan for the Assay, in a form to be determined by the JSC (the Assay Commercialization Plan). During the Term, Microgenics shall provide Achaogen [***] with (i) an updated Launch Plan [***], and (ii) an updated Assay Commercialization Plan  [***]. For clarity, (i) the Launch Plan and Assay Commercialization Plan shall be Confidential Information of Microgenics hereunder, and (ii) Microgenics is  [***] in preparing and conducting activities under the Launch Plan and Assay Commercialization Plan.

4.2.5 Geographies. Other than the Primary Countries set forth on Exhibit E, the Parties shall mutually agree upon any Secondary Countries where Achaogen plans to introduce Plazomicin, which such Secondary Countries shall thereafter be deemed to be Primary Countries and included in the Plazomicin Commercialization Plan and the Assay Commercialization Plan, in all cases no later than [***] prior to the anticipated launch of Plazomicin in any such country; provided, however, the parties agree that actual product registration may take longer than [***] ([***]) months.

4.2.6 Selling, Marketing and Customer Support to Clinical Labs.  Microgenics will establish and maintain a commercial infrastructure for the supply of the Assay, as well as adequate product support, customer support and regulatory support in each market where the Assay is introduced, including [***]. For clarity, Achaogen [***] the Assay to physicians and other prescribers and related individuals and organizations; provided, that, for clarity, Microgenics [***] of the Assay to any such physicians or other prescribers or related individuals and organizations.

Page 12 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   4.2.7 Abandoned or Uninitiated Development or Commercialization of Assay.

4.2.7.1 If, during the Term, Achaogen determines in good faith that Microgenics has ceased to develop, commercialize and market the Assay in a specific country within the Territory in which Achaogen has obtained or is in the process of obtaining Regulatory Approval for Plazomicin for a period of at least [***] ([***]) months (Abandoned Commercialization or Abandoned Development, as applicable), then Achaogen may deliver to Microgenics written notice that Achaogen deems Microgenics to have Abandoned Commercialization. If Achaogen delivers such written notice to Microgenics, such notice shall set forth the basis for Achaogen's good faith determination. If Microgenics disagrees with Achaogen's determination that Microgenics has Abandoned Commercialization, then the Parties will meet within  [***] ([***]) business days to discuss such disagreement. If the Parties cannot agree after such discussion, then the terms of Section 13.8 shall apply to resolve such Dispute.

4.2.7.2 If it is finally determined pursuant to the procedures set forth in Section 4.2.7.1 that Microgenics has Abandoned Commercialization, then, within [***] ([***]) business days of such determination, Microgenics will commercialize and market the Assay for  [***] ([***]) months after the written determination is received. After the [***]  ([***]) months period has expired, Microgenics will continue to supply the Assay to Achaogen or its distributor pursuant to the terms of a supply agreement that the Parties will negotiate during the first [***] ([***]) months of the [***] month period described in the prior sentence; provided, that such supply agreement shall include an initial (i.e., for a period of no less than  [***]  ([***]) months) supply price that is no greater than  [***]  ([***]%) of the lowest price at which Microgenics has made the Assay available to its distributors, or any Third Party if there is no distributor, in the affected country.  Microgenics shall  [***] promptly assist Achaogen (and/or its designee) in obtaining all necessary Regulatory Approvals and/or modifying and/or transferring existing Regulatory Approvals to enable Achaogen (and/or its designee) to develop, make, have made, use, market, distribute, import, sell and offer for sale the Assay ([***]) in any applicable country.

4.2.7.3 Solely in the event of Abandoned Development, the Parties acknowledge and agree that this Agreement does not supersede Section 5.3 of the Antibody Development Agreement and that Achaogen reserves all of its rights under Section 5.3 of the Antibody Development Agreement, including in the event of Abandoned Development.

4.3 Supply.   4.3.1 Clinical Supply. Microgenics shall supply to Achaogen the amount of Assay ordered by Achaogen, if any, for use in any clinical trials or other development of Plazomicin in accordance with the delivery and shipment terms set forth in the Project Plan to the extent applicable. Achaogen shall provide to Microgenics confidential, non-binding good faith clinical trial and other development supply forecasts for each [***] ([***]) month period starting on [***] and [***] of each calendar year and shall deliver each forecast in writing at least [***] ([***]) days prior to the commencement of the applicable [***] ([***]) month period. The Parties shall agree on the exact date for the delivery of such Assay. Achaogen shall reimburse Microgenics at (a) a price of USD $[***] per patient result used to make diagnostic decisions for the applicable patient or (b) in the event the Assay is being commercialized at the time of supply, [***]; provided, however, in each case, if Microgenics utilizes any data from any clinical trial or other study conducted by Achaogen with Assay supplied under this Section 4.3.1, Achaogen shall have no obligation to reimburse Microgenics for such Assay.

Page 13 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   4.3.2 Continued Supply.

4.3.2.1 Microgenics shall ensure the continued worldwide supply of the Assay in quantities at least sufficient to meet each applicable Binding Forecast. Without limiting the foregoing, Microgenics agrees to maintain a safety stock of rare reagents sufficient to meet each applicable Binding Forecast for the Assay. Microgenics shall provide Achaogen at least [***] ([***]) months (or [***]) prior written notice of any possible shortfall in meeting each applicable Binding Forecast or other commercial demand for the Assay, and the Parties shall promptly meet and discuss all reasonable commercial resolutions if Microgenics is unable to assure supply as needed to meet each applicable Binding Forecast pursuant to the terms set forth in Section 4.3.2.2.

4.3.2.2 In addition, in order to ensure security of supply of the Assay, within  [***]  o f Microgenics' receipt of the first Regulatory Approval for the Assay in any country in the Territory, Microgenics shall designate [***] (the Back-up Supplier) which such Back-up Supplier shall be and remain qualified as a manufacturer of the Assay for the supply of the Assay for sale in the Territory. Microgenics shall [***] ensure that the Back-up Supplier can supply the Assay for sale in the Territory within [***] days. Microgenics will develop a manufacturing transition plan that will highlight [***] needed to complete the transition to the back-up supplier. This plan will be presented to the JSC prior to first commercial launch of the Assay.

4.3.2.3 If, for any reason, [***], both Microgenics and the Back-up Supplier (as applicable) are unable to supply the Assay in quantities sufficient to meet the quantities of the Assay either (a) as set forth in each applicable Binding Forecast or (b) based on such other measure of commercial demand as agreed to by the Parties in writing, in either case, during any given  [***]  ([***]) month period for a given country in the Territory, then Microgenics hereby grants Achaogen or its designee a Shortfall License, which license shall survive until [***] ([***]) months following the date that either Microgenics or the Back-up Supplier (as applicable) is in a position again to fulfill such demand (as such positioning is demonstrated [***]) (the Supply Resumption Date). The Shortfall License shall expire automatically [***] ([***]) months after the Supply Resumption Date; provided, however, that (a) Achaogen shall be entitled to use, sell, offer for sale, and import any assay that are in inventory prior to the expiration of the Shortfall License (even if such activity occurs after expiration of the Shortfall License). Additionally, [***], Microgenics shall (i) make its personnel available for a reasonable period of time (not to exceed  [***]  ([***]) months) to effect a successful technology transfer with respect to the manufacture and commercialization of such Assay under the terms of this paragraph, (ii) provide Achaogen with copies of the physical embodiment of all processes, protocols, procedures, methods, tests and other intellectual property rights licensed to Achaogen under the Shortfall License, as applicable, related to Assay (including the manufacture thereof), (iii) supply [***] (including [***]) reasonably required to perform [***] as may be required by the applicable Regulatory Authorities, and upon request by Achaogen,  [***], provide Achaogen (and/or its designee) with  [***] related to the Assay, and (iv) promptly assist Achaogen (and/or its designee) in obtaining all necessary Regulatory Approvals and/or modifying and/or transferring existing Regulatory Approvals to enable Achaogen (and/or its designee) to develop, make, have made, use, market, distribute, import, sell and offer for sale the Assay ([***]).

4.4 Audit Rights.   4.4.1 [***] during the Term, commencing on the  [***] ([***]) [***] of the Effective Date, Achaogen shall have the right to inspect and audit  [***] per calendar year (either by itself or through a Third Party reasonably acceptable to Microgenics) the Assay manufacturing process, facilities, procedures,

Page 14 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   and records upon reasonable notice (which shall be no less than [***] ([***]) calendar days prior notice, unless a shorter period is mutually agreed to by the Parties), and during normal business hours. Notwithstanding the foregoing, Achaogen shall have the right to conduct for cause audits (either by itself or through a Third Party reasonably acceptable to Microgenics)  [***] during normal business hours of the [***], including in the event of a failure to supply the Assay as specified under Section 4.3.2. Any information shared with Achaogen or a Third Party under this Section 4.4.1 shall be considered Confidential Information. In connection with any such inspection or audit, Microgenics shall have no obligation to provide Achaogen and/or a Third Party access to Microgenics' Confidential Information related to any product other than the Assay.    4.4.2 Additionally, during the Term, Microgenics shall inform Achaogen within [***] ([***]) business days after receipt of any notice of an audit or inspection by ay Regulatory Authority which directly or indirectly relates to the Assay or the Assay manufacturing or distribution operations and Microgenics shall promptly provide to Achaogen in writing the results of any such audit or inspection within [***] ([***]) business days of receipt, including (a) a copy of any inspection reports, Form 483s, warning letters or similar such reports or warnings (Audit Outcome), to the extent such Audit Outcome solely addresses the Assay, or (b) a summary of such Audit Outcome, including verbatim text copies of portions thereof pertaining to the Assay, to the extent such Audit Outcome addresses the Assay and other matters, or (c) a summary of such Audit Outcome, to the extent that the Assay is not mentioned in such Audit Outcome; provided, that, in each case of clauses (a), (b), and (c), Microgenics' may redact from such copies or reports information that does not relate to the Assay, Plazomicin or this Agreement and the activities hereunder, and a summary of Microgenics proposed strategy for addressing any issues or violations noted during the course of such audit or inspection.   4.5 Labeling.   4.5.1 Assay Labeling. Microgenics shall be responsible for ensuring that all Assay packaging and labeling are in compliance with its Regulatory Approvals and Applicable Law.   4.5.2 Information for Labeling and Promotional Materials for Plazomicin.  At the request of Achaogen, Microgenics shall provide to Achaogen such information related to the Assay which is in Microgenics' possession, for Achaogen's use and reference in the packaging and labeling (including package insert) and promotional materials for Plazomicin.

4.5.3 Changes to Labeling. Achaogen will promptly notify Microgenics of any changes to Plazomicin labeling relevant for the Assay, including  [***].  [***], such changes will be implemented by Achaogen with  [***] in order to allow Microgenics to change any labeling on the Assay as a result of such changes to Plazomicin labeling. Similarly, Microgenics will promptly notify Achaogen of any changes to the Assay labeling, and Microgenics will implement such changes with [***] in order to allow Achaogen to change any labeling on Plazomicin as a result of such changes to the Assay labeling; provided, however, that Microgenics shall not make any such changes directed to Plazomicin (including, [***]) or which would otherwise require a change to the labeling for Plazomicin, without Achaogen's prior written approval.

5 Governance.   5.1 Alliance Managers.   5.1.1 No later than [***] ([***]) days after the Effective Date, each of the Parties shall

Page 15 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   appoint one (1) representative as its alliance manager (Alliance Manager). The Alliance Managers shall have the right to attend all JSC and JPT meetings as non-voting participants and may bring to the attention of the JSC or JPT any matters or issues either of them reasonably believes should be discussed, and shall have such other responsibilities as set forth in Section 5.1.2 or as the Parties may mutually agree. Each Party may replace its Alliance Manager at any time or may designate different Alliance Managers by notice in writing to the other Party.    5.1.2 The Alliance Managers shall have responsibility for creating and maintaining a constructive work environment between the Parties. Without limiting the generality of the foregoing, each Alliance Manager shall:   5.1.2.1 identify and bring disputes and issues, including disputes that cannot be resolved by the JPT, that may result in disputes to the attention of the JSC in a timely manner, and function as the point of first referral in all matters of conflict resolution. In doing so, it is not intended that the Alliance Manager(s) act as a substitute for, or insert any delay in, the formal dispute resolution mechanisms set forth in Section 13.8, but rather that the Alliance Manager(s) shall endeavor to maintain a positive and constructive relationship between the Parties at the working level;   5.1.2.2 provide a single point of communication for seeking consensus both internally within the Parties' respective organizations and between the Parties;

5.1.2.3 plan and coordinate cooperative efforts, internal communications and external communications between the Parties with respect to this Agreement; and

5.1.2.4 take responsibility for ensuring that meetings and the production of meeting agendas and minutes occur as set forth in this Agreement, and that relevant action items resulting from such meetings are appropriately carried out or otherwise addressed.

5.2 Joint Steering Committee. The Parties agree that the Research Program shall be managed by a Joint Steering Committee (JSC) and that the JSC shall otherwise have responsibility for the general oversight of activities hereunder. No later than [***] ([***]) days after the Effective Date, each of the Parties shall appoint two (2) representatives to the JSC. The JSC shall be led by two (2) co-chairs, one (1) appointed by Microgenics and one (1) appointed by Achaogen. The JSC will make decisions by consensus, with Microgenics and Achaogen each having one vote. In the event of an impasse, the matter shall be resolved pursuant to Section 5.2.3 (Decision-Making). A Party may change any of its representatives at any time by giving [***] ([***]) days prior written notice to the other Party.   5.2.1 Responsibilities. In addition to its general responsibility to oversee and coordinate the development of the Assay according to the Project Plan and to assure the regular flow of information between the Parties, the JSC shall:   (a) develop the Project Plan, monitor the progress of the Research Program, and review and approve all proposed changes to the Project Plan;   (b) amend the Specifications for the Assay;   (c) review and approve the [***] in accordance with Section [***] hereof;   (d) oversee the activities of the JPT;   (e) review and approve the most appropriate regulatory pathway for obtaining Regulatory

Page 16 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     Approval of the Assay;   (f) review and approve the contents of all applications for Regulatory Approval and related and supporting submissions to Regulatory Authorities;   (g) develop and manage clinical samples supply;   (h) discuss pricing policy for the Assay in the Territory, including  [***] and similar matters, to the extent permitted under Applicable Law; provided that, for clarity, [***];   (i) resolve disputes escalated by the Alliance Managers; provided that, if after [***], the JSC is unable to resolve any such dispute, such dispute shall be resolved in accordance with Section 5.2.3.2;   (j) confirm completion of each event described in Section 7.1 if the Joint Project Team has not agreed that a Milestone has been completed; and   (k) manage and coordinate the supply and commercialization of the Assay, including the initial commercial launch of the Assay and monitoring the progress of the Assay Commercialization Plan and Launch Plan.   5.2.2 Meetings. The JSC shall meet at least [***] during the Term at such place and time as is agreed upon by the Parties; provided, however, that in the event of an emergent situation, including a situation in which a decision by the JSC is required, a meeting shall be held within [***] ([***]) days after written request for such meeting by either Party. Meetings of the JSC may be conducted in person, by telephone or videoconference as agreed by the JSC or the Parties. When held in person, the location of the meetings shall alternate between Achaogen's facilities and Microgenics' facilities, unless otherwise mutually agreed by the Parties. The Alliance Managers shall be responsible for planning and scheduling the meetings and preparing the agenda. The Alliance Managers will record the minutes of each meeting (alternating between Achaogen and Microgenics). Minutes of each meeting of the JSC shall be exchanged for review, comment and approval by the members; provided that, if after [***] ([***]) days following the distribution of the minutes, neither Party has raised any objection, the minutes shall be deemed to have been approved by the Parties. Thereafter, the minutes shall be signed by the co-chairs and distributed to each of the Parties. Additionally, upon invitation by the JSC, the Functional Leaders (or other JPT members) may attend JSC meetings as non-voting members, and each JSC member may reasonably invite other guests to the meetings, in order to discuss special technical or commercial topics relevant to the applicable agenda; provided, that any guests are subject to the confidentiality provisions set forth in Article 12 (Confidentiality).   5.2.3 Decision-Making.   5.2.3.1 All decisions of the JSC shall be made in good faith in the interest of furthering the purposes of this Agreement and the JSC members shall use good faith efforts to make decisions unanimously.   5.2.3.2 If the JSC is unable to agree on any matter after good faith attempts to resolve such disagreement [***], then for matters that are [***], the JSC may refer the disagreement to a meeting between a senior executive (other than a JSC member) representing each Party (currently [***] for Achaogen and [***] for Microgenics) which meeting shall take place as soon as practicable, but in no event later than [***] ([***]) days after the date of the relevant referral. If the senior executives for Achaogen and Microgenics cannot resolve such disagreement over such [***] matter in a mutually acceptable manner within  [***]  ([***]) business days after such meeting then the matter shall be decided in accordance with Section 13.8.2. Notwithstanding the foregoing, except as otherwise provided in, and subject to the terms and conditions of, this Agreement: (a) [***], with appropriate consideration of the interests of [***], will have [***] that impact the development,

Page 17 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   manufacture or marketing of [***] and (b) [***], with appropriate consideration of the interests of [***], will have [***] that [***] impact the development, manufacture or marketing of [***]; provided, that, [***] shall not have decision-making authority regarding (i) [***], or (ii) [***], which such decisions shall require the mutual agreement of the Parties, or (iii) [***] (which the Parties acknowledge will be ultimately dictated by [***]), or (iv) [***].    5.2.4 Expenses. Microgenics and Achaogen shall be responsible for all expenses incurred by its JSC members in connection with performing their duties hereunder, including all costs of travel, lodging and meals.   5.2.5 No Authority to Amend. For the avoidance of doubt, the JSC (and any Party exercising decision-making authority under Section 5.2.3.2) shall not have the authority to amend this Agreement, but the JSC shall have authority to amend the Project Plan and the Specifications as expressly set forth herein (and, for clarity, [***] shall not have decision-making authority with respect to any [***]).   5.3 Joint Project Team; Functional Leaders.   5.3.1 Formation. The Parties shall form a joint project team (the Joint Project Team or JPT). The JPT shall be comprised of a total of six (6) project team members from Microgenics and Achaogen, with Microgenics and Achaogen each designating a development leader, a regulatory leader, and a commercial leader (respectively, the Development Leader, the Regulatory Leader and the Commercial Leader, and collectively, the Functional Leaders) who shall be the principal point of contact for each Party for matters relating to its respective function, and shall be responsible for implementing and coordinating, on a day-to-day basis, all activities and facilitating the exchange of information between the Parties regarding the Project Plan for his or her function. Notwithstanding the foregoing, the Regulatory Leaders and Commercial Leaders may be appointed at such time as the Parties deem appropriate to facilitate the development of the Assay and a successful commercial launch of Plazomicin and the Assay.   5.3.2 Responsibilities. The JPT shall have responsibility for coordinating all development, regulatory, commercial and other business and technical activities under this Agreement. In addition to its general responsibility to deliver the development of the Assay according to the Project Plan and to assure the regular flow of information between the Parties, the JPT shall:     (a) recommend changes to the Project Plan, Launch Plan and Assay Commercialization Plan to the JSC,   (b) monitor the activities vs budget to the JSC,   (c) recommend changes to the Specifications for the Assay to the JSC;   (d) communicate progress to the JSC;   (e) plan the regulatory pathway for obtaining Regulatory Approval of the Assay; and   (f) prepare all applications for Regulatory Approval and related and supporting submissions to Regulatory Authorities.   5.3.3 Members. No later than [***] ([***]) days after the Effective Date, each Party shall provide the other with the names of its JPT members and Functional Leaders (other than the Regulatory Leaders and Commercial Leaders). Microgenics and Achaogen may replace its JPT members and Functional Leaders at any time and for any reason upon written notice to the other Party.   5.3.4 Sub-Teams. The JPT and Functional Leaders may delegate tasks and

Page 18 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   responsibilities to sub-managers, working groups and other team members as they deem appropriate to efficiently and effectively perform their respective obligations hereunder.   5.3.5 Meetings. The JPT shall meet as soon as practicable after the Effective Date and thereafter during the performance of the Project Plan, at least [***], and at such additional times as the JPT or the Parties reasonably deem appropriate; provided, that, following the completion of the Project Plan, the JPT shall continue to meet no less frequently than [***]. Meetings of the JPT may be conducted in person, by telephone or videoconference as agreed by the JPT or the Parties. Additionally, the JPT and the Functional Leaders (or their designees) shall maintain close regular communications with each other as to the status of the ongoing and planned activities under the Project Plan, Launch Plan and Assay Commercialization Plan. Each JPT member may reasonably invite other guests to the meetings, in order to discuss special technical or commercial topics relevant to the applicable agenda; provided, that any guests are subject to the confidentiality provisions set forth in Article 12.   5.3.6 No Authority to Amend.  Neither the JPT nor the Functional Leaders (or their designees) shall have authority to amend this Agreement or the Project Plan, but may make recommendations regarding such amendments to the JSC.   5.3.7 Dispute Resolution. The JPT and the Functional Leaders will cooperate with each other and work in good faith to resolve any disagreements between them or their respective teams. Any such disagreements that are not resolved by the JPT shall be raised to the Alliance Managers for internal escalation if needed.   5.3.8 Records. The JPT shall keep accurate and complete records of their activities and meetings and shall, from time to time as requested by the JSC, provide the JSC with appropriate updates and information to keep the JSC apprised of the progress of the Project Plan, Launch Plan and Assay Commercialization Plan. All records of the JPT that are disclosed to the other Party and which relate to the Project Plan shall be available at all times to the JSC and to each Party on a confidential basis solely for use with respect to such Party's activities conducted pursuant to this Agreement.   5.3.9 Expenses. Microgenics and Achaogen shall be responsible for all expenses incurred by its JPT members in connection with performing their duties hereunder, including all costs of travel, lodging and meals.   5.4 Reporting. The Parties shall keep each other promptly informed on an ongoing basis through the Joint Project Team and the JSC on the progress of the Project Plan, the Launch Plan and the Assay Commercialization Plan, including forecasts of expected performance and completion of activities. Without limiting the foregoing, within [***] ([***]) days following [***] of each calendar year during the Term, Microgenics shall provide to Achaogen a written progress report in English, in a form to be agreed upon by the JSC, which shall include any information required under the Project Plan and as otherwise reasonably determined by the JSC relating to the progress of the goals or performance of the development, commercialization and other activities under the Project Plan, the Launch Plan and the Assay Commercialization Plan.   6 Grant of License   6.1 Exclusive License by Achaogen. During the Term, and without limiting Section 4.2, Achaogen hereby grants to Microgenics a royalty-free, exclusive, worldwide license to use the Achaogen

Page 19 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Know-How, Achaogen Patents, and Achaogen Materials to research, develop, manufacture, use, market and sell the Assay in the Territory. [***].    6.2 License by Microgenics. During the Term, Microgenics hereby grants to Achaogen and its Affiliates a royalty- free, non-exclusive, sub-licenseable, worldwide license, under and with respect to the Immunoassay Technologies, Microgenics Know- How and any Patents or Patent applications Controlled by Microgenics or its Affiliates to the extent reasonably necessary for Achaogen to perform its obligations or exercise its rights under this Agreement or as is otherwise reasonably necessary to make, have made, use, sell, offer for sale, import and otherwise commercialize Plazomicin. For the avoidance of doubt, the foregoing license grant does not provide any license or right for Achaogen to make, have made, use, sell, offer for sale, import or otherwise commercialize the Assay, except in connection with Achaogen's exercise of the Shortfall License or Transfer License.   6.3 [***] Products and Joint Patents. Each Party shall be entitled to grant non-exclusive licenses to any Third Party under its interest in a  [***] Products or Joint Patent  [***]. [***], and if in certain countries the grant of a license, in order to be effective, requires declarations from the other Party, the other Party shall reasonably cooperate and provide the necessary declarations.   6.4 No Implied License. Achaogen retains all rights in and to the Achaogen Patents and Achaogen Know-How. Microgenics retains all rights in and to the Immunoassay Technologies and Microgenics Know-How. Only the licenses and other rights expressly granted by one Party to the other Party under terms of this Agreement are of any legal force or effect. No other licenses or other rights are granted, conveyed or created (whether by implication, estoppel or otherwise).   7 Consideration to Microgenics    7.1 Development Payments.  In consideration of the development efforts of Microgenics under the Research Program, Achaogen shall pay to Microgenics the following one-time payments upon the occurrence of the corresponding events:     (a) USD $[***] upon the successful completion of Phase 0:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for Phase 0;     (b) USD $[***] upon the successful completion of Phase 1:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for Phase 1;     (c) USD $[***] upon the successful completion of Phase 2:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for Phase 2;      (d) USD $[***] upon the successful completion of Phase 3:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for Phase 3;     (e) USD $[***] upon the successful completion of the first milestone of Phase 4:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of

Page 20 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     all deliverables required by the Project Plan for the first milestone of Phase 4;     (f) USD $[***] upon the successful completion of the second milestone of Phase 4: [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for the second milestone of Phase 4;     (g) USD $[***] upon the successful completion of the third milestone of Phase 4:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for the third milestone of Phase 4;     (h) [***],  USD $[***] upon the successful completion of the fourth milestone of Phase 4:  [***]  a s determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for the fourth milestone of Phase 4;     (i) USD $[***] upon the successful completion of the first milestone of Phase 5:  [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for the first milestone of Phase 5;     (j) USD $[***] upon the successful completion of the second milestone of Phase 5: [***] as determined in accordance with the Project Plan, including delivery by Microgenics of all deliverables required by the Project Plan for the second milestone of Phase 5;     (k) [***]; and     (l) [***] and assuming [***], USD $[***] upon [***]; provided, however, this amount [***].   Thereafter, no additional payments shall be due and payable to Microgenics by Achaogen for any Assay [***].   7.2 Invoices; Mechanism of Payment. Upon the completion of each event as described in Section 7.1, Microgenics will invoice Achaogen within [***] ([***]) business days. Microgenics agrees to submit invoices to Achaogen (on a timely basis) for all payments due hereunder. Invoices shall reference Achaogen's contract number and the purchase order number. The invoices due under this Agreement shall be submitted to:   Achaogen Inc. 7000 Shoreline Court, #371 South San Francisco, CA 94080   Reference: Achaogen Contract No. _____________, Attn.: _______ Email:   All payments due Microgenics under this Agreement shall be made by Achaogen in United States dollars within [***] ([***]) days after receipt of the applicable invoice by ACH transfer to the credit and account of Microgenics at the following account: [***].

Page 21 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   7.3 Taxes.   7.3.1 Withholding. Microgenics shall be liable for all income and other taxes (including interest) imposed upon any payments made by Achaogen to Microgenics under this Agreement. In the event that any Applicable Law requires Achaogen to withhold taxes with respect to any payment to be made by Achaogen pursuant to this Agreement, Achaogen will notify Microgenics of such withholding requirement prior to making the payment to Microgenics and provide such assistance to Microgenics, including the provision of such documentation as may be required by a tax authority, as may be reasonably necessary in Microgenics' efforts to claim an exemption from or reduction of such taxes. Achaogen will, in accordance with such Law withhold taxes from the amount due, remit such taxes to the appropriate tax authority, and furnish Microgenics with proof of payment of such taxes within [***] ([***]) days following the payment. If taxes are paid to a tax authority, Achaogen shall provide reasonable assistance to Microgenics to obtain a refund of taxes withheld, or obtain a credit with respect to taxes paid.   7.3.2 VAT. All payments due to Microgenics from Achaogen pursuant to this Agreement shall be paid exclusive of any value-added tax (VAT) (which, if applicable, shall be [***]). If Microgenics is required to report any such tax, Achaogen shall promptly provide Microgenics with applicable receipts and other documentation necessary or appropriate for such report.   8 Intellectual Property Rights; Ownership   8.1 Ownership of Discoveries and Inventions. Achaogen shall own all discoveries and inventions made by one or both of the Parties as part of the Research Program, whether or not patentable, relating (i) solely to Plazomicin, the Achaogen Patents, the Achaogen Know-How, and Achaogen Materials or (ii) [***] (each of (i) and (ii), Achaogen Inventions). Microgenics shall own all inventions and discoveries made by one or both of the Parties as part of the Research Program, whether or not patentable, relating solely to Microgenics Cell Lines, Microgenics [***] Antibodies, the Assay, Immunoassay Technologies and Microgenics Know-How (Microgenics Inventions). For all other inventions and discoveries, whether or not patentable, made by the Parties as part of the Research Program, whether individually or jointly, inventorship shall be determined pursuant to the inventorship principles arising under the patent laws of the United States of America, [***] ([***] Products). Each Party shall ensure that each of its employees and other representatives performing activities hereunder has agreed to assign to it all discoveries and inventions made by such employee or other representative in the course of his or her employment.   8.2 Patent Procurement.   8.2.1 Achaogen and Microgenics shall each disclose to the other any inventions and discoveries made during the course of the Research Program. Achaogen shall be responsible for the prosecution and maintenance of any Patent applications and Patents claiming or covering any Achaogen Inventions, and Microgenics shall be responsible for the prosecution and maintenance of any Patent applications and Patents claiming or covering any Microgenics Inventions; provided, that  [***] shall not, without first obtaining [***] prior written consent, file any Patent claiming or covering the [***]; provided, further, that, in the event that any such Patent applications covering or claiming any  [***] are filed without first obtaining  [***] prior written consent, then  [***] hereby grants [***] a perpetual, irrevocable, fully paid-up, royalty-free, worldwide, sublicenseable, non-exclusive license under such Patent applications and any Patents issuing therefrom or related thereto for the purpose of developing, manufacturing, using or commercializing [***].

Page 22 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     8.2.2 With respect to any Patent applications and Patents claiming or covering any [***] Products, the Parties shall meet to determine in what countries, if any, Patent applications claiming such [***] Products should be filed and the appropriate filing Party (a Joint Patent). The Parties shall [***] by the Party filing such patent applications in connection with any Joint Patents. If a Party elects [***] related to any Joint Patent, the other Party shall provide written notice upon the decision to [***] and the Party not giving such notice shall have the right to assume responsibility for any such prosecution or maintenance, [***].   8.3 Prosecution, Review, Cooperation.   8.3.1 The Party responsible for prosecuting and maintaining a given Patent pursuant to Section 8.2.1 or 8.2.2 (i.e., Microgenics with respect to Patents claiming or covering any Microgenics Inventions and the Assay Patent and the Party agreed to by the Parties with respect to Joint Patents) (the Responsible Party) shall keep the other Party (the Review Party) reasonably informed regarding the status of the filing, prosecution and maintenance of each applicable Patents, and shall provide the Review Party with copies of all documentation concerning each applicable Patent, including all correspondence to and from any Governmental Authority relating thereto. Prior to filing an applicable Patent application for, or material prosecution documents or other submissions relating to, an applicable Patent, the Responsible Party shall provide the Review Party with a reasonable opportunity to review and comment on the proposed application, document or submission, and the Responsible Party shall reasonably consider all such comments and incorporate such comments. In the event that the Responsible Party elects to abandon any applicable Patent, the Responsible Party shall notify the Review Party in writing (such notice, an Abandonment Notice) at least  [***]  ([***]) days prior to any filing or payment due date or any other due date that requires action to prevent loss of rights, and in the event that the Review Party provides the Responsible Party with written notice within  [***] ([***]) days of receipt of the applicable Abandonment Notice, the Review Party shall thereafter have the right, [***], to conduct such filing, prosecution and maintenance for the applicable Patent.   8.3.2 Each of the Parties shall execute or have executed by its employees, representatives and agents such documents as may be reasonably necessary to obtain, perfect, or maintain any Patent rights which would be filed pursuant to this Agreement and to cooperate with the other Party, [***], as reasonably necessary with respect to the prosecution of such Patent rights.   8.4 Ownership. The Achaogen Patents, Achaogen Know-How and the Achaogen Materials shall at all times remain the sole property of Achaogen. Microgenics shall not use the Achaogen Know-How or the Achaogen Materials to develop or market, or have developed or marketed, any Assay for any Third Party. The Microgenics Cell Lines, Microgenics  [***] Antibodies, Immunoassay Technologies and Microgenics Know-How shall remain the sole property of Microgenics. Except as may otherwise be expressly permitted pursuant to the terms and conditions of this Agreement, Achaogen shall not use the Microgenics Cell Lines, Microgenics Monoclonal Antibodies, Immunoassay Technologies and Microgenics Know-How to develop, manufacture, or market, or have developed, manufactured, or marketed, the Assay or any additional assay(s) for Plazomicin or any other compound/substance.   8.5 Enforcement. Each Party shall immediately notify the other if it becomes aware of any infringement, anywhere in the world, of any issued Patent within the Joint Patents. The Parties shall mutually determine whether to take action to obtain a discontinuance of infringement or bring suit against a Third Party infringer of any Joint Patents within [***] ([***]) days from the date of notice; provided that neither

Page 23 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Party shall be obligated to join any such action. In the event that either Party does not want to join as a Party plaintiff, then the Party not seeking to enforce such infringement claims shall have the right to assign the relevant Joint Patents to the other Party; provided that such assignment is solely and sufficient for purposes of commencing and maintaining the action. The Party seeking to enforce such infringement claims [***] of any suit brought by it claiming infringement of any Joint Patent. The Parties will reasonably cooperate, at the expense of the Party seeking to enforce such infringement claim, in any such suit and shall have the right to consult with the other Party and to participate in and be represented by independent counsel in such litigation [***]. Any recoveries obtained by Achaogen or Microgenics, as applicable, as a result of any proceeding against such a Third Party infringer shall be allocated as follows: (a) such recovery shall first be used to reimburse each Party for all reasonable attorney fees and other litigation costs actually incurred in connection with such litigation by that Party, and (b) any remainder shall be shared [***] by the Parties.   8.6 Patent Infringement. Each Party shall immediately notify the other if a claim or other proceeding is brought against either Party alleging infringement of Third Party Patent rights based upon the manufacture, use or sale of the Assay. The Parties shall immediately consult on how to proceed with respect to defending against any such claim of infringement.   8.7 Third Party Licenses. Microgenics shall be solely responsible, at its own expense, for obtaining rights under any Third Party intellectual property necessary for Microgenics to perform its obligations under this Agreement and Achaogen shall be under no obligation to provide support therefor, financial or otherwise.   8.8 Trademarks. As between the Parties, Microgenics shall own all right, title and interest in and to any Trademarks developed by or for Microgenics for use in connection with the Assay. Microgenics hereby grants to Achaogen a royalty-free non- exclusive right to use such Trademarks in connection with advertising, promoting and marketing Plazomicin, subject to Section 12.5 (Non-Use of Names). All use of Microgenics' Trademarks by Achaogen shall inure to the sole benefit of Microgenics. As between the Parties, Achaogen shall own all right, title and interest in and to all Trademarks developed by or for Achaogen for use in connection with Plazomicin.   9 Term and Termination    9.1 Term. This Agreement shall be effective as of the Effective Date and unless terminated earlier by mutual written agreement of the Parties or pursuant to Section 9.2 (Termination At Will) or Section 9.3 (Termination for Cause) below, the term of this Agreement shall continue in effect until Achaogen ceases development and commercialization of Plazomicin (Term).   9.2 Termination At Will. Achaogen may terminate this Agreement in its entirety, for any reason, by providing at least sixty (60) days prior written notice to Microgenics.   9.3 Termination for Cause. This Agreement may be terminated in its entirety by written notice by either Party at any time:   9.3.1 For material breach by the other Party, which breach remains uncured for ninety (90) days from the date written notice of such breach is given to the breaching Party, or, if such breach is not susceptible of cure within such ninety (90) day period and the breaching Party uses diligent good faith efforts to cure such breach, for one hundred eighty (180) days after written notice to the breaching Party if such breach remains uncured; or

Page 24 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     9.3.2 Upon the filing or institution of bankruptcy, reorganization, liquidation or receivership proceedings, or upon an assignment of a substantial portion of the assets for the benefit of creditors by the other Party, or in the event a receiver or custodian is appointed for such Party's business, or if a substantial portion of such Party's business is subject to attachment or similar process; provided, however, that in the case of any involuntary bankruptcy proceeding such right to terminate shall only become effective if the proceeding is not dismissed within sixty (60) days after the filing thereof.   9.4 Effect of Termination.  Upon termination of this Agreement pursuant to Sections 9.1 (Term), Section 9.2 (Termination At Will) or 9.3 (Termination for Cause):   9.4.1 All rights and licenses granted under Section 6.1 (License by Achaogen) of this Agreement shall terminate and all rights to the Achaogen Patents and Achaogen Know-How shall revert to Achaogen.   9.4.2 All rights and licenses granted under Section 6.2 (License by Microgenics) of this Agreement shall terminate and, subject to Section 9.4.4, all rights to the Immunoassay Technologies and Microgenics Know-How shall revert to Microgenics.   9.4.3 Microgenics shall promptly return or destroy (as directed by Achaogen) to Achaogen all Achaogen Know- How and Achaogen Materials provided to Microgenics hereunder, and, subject to Section 9.4.4, Achaogen shall promptly return to Microgenics all Microgenics Know-How provided to Achaogen hereunder;   9.4.4 Solely in the case of termination of this Agreement by Achaogen under Section 9.3 (Termination for Cause):   9.4.4.1 Microgenics hereby grants Achaogen a Transfer License; provided, that, Achaogen covenants not to use the Transfer License beyond the scope set forth in Section 1.33. In the event that Microgenics reasonably believes that Achaogen has breached the foregoing covenant, Microgenics shall provide written notice thereof, including reasonable supporting evidence, and, in the event that Achaogen agrees with such written notice and does not indicate to Microgenics that it will conform its activities to the scope of the Transfer License within [***] ([***]) business days after receiving the written notice, then the Transfer License shall be void as of the end of [***] period described in this sentence. If Achaogen indicates that it will so conform its activities, then the Transfer License shall remain in full force and effect. In the event that Achaogen disagrees with such written notice and advises Microgenics of such disagreement, the Parties shall submit this matter to the Dispute resolution process in 13.8. For purposes of resolving any disputes regarding the Transfer License, the Parties agree to complete the Dispute resolution process in 13.8 within  [***] from the date of Microgenics' first written notice of the breach of the covenant found in the proviso to the first sentence of this Section 9.4.4.1(i). If after concluding the Dispute resolution process in 13.8 it is determined that the covenant found in the proviso was breached, then the Transfer License shall terminate immediately.  In the event that the Transfer License is granted, Achaogen shall owe no payments to Microgenics for the first [***] ([***]) months that any Assay commercialized under the Transfer License is commercialized and shall pay a [***] percent ([***]%) royalty on its net sales (i.e., gross sales less all deductions, reductions and offsets reasonably taken in accordance with generally accepted accounting principles in the United States) of Assays commercialized under the Transfer License following the end of such [***] ([***]) month

Page 25 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   period.   9.4.4.2 Microgenics shall (a) make its personnel available for a reasonable period of time (not to exceed  [***]  ([***]) months) to effect a successful technology transfer with respect to the manufacture and commercialization of the Assay, (b) provide Achaogen with copies of the physical embodiment of all processes, protocols, procedures, methods, tests and other intellectual property rights licensed to Achaogen under the Transfer License, as applicable, related to the Assay (including the manufacture thereof), (c) supply [***] (including [***]) reasonably required to perform  [***] as may be required by the applicable Regulatory Authorities, and upon request by Achaogen,  [***], provide Achaogen (and/or its designee) with  [***] related to the Assay, and (d) promptly assist Achaogen (and/or its designee) in obtaining all necessary Regulatory Approvals and/or modifying and/or transferring existing Regulatory Approvals to enable Achaogen (and/or its designee) to develop, make, have made, use, market, distribute, import, sell and offer for sale the Assay ([***]).   9.4.4.3 If, at the date of the actual termination of this Agreement, Microgenics is commercializing the Assay, such termination shall be suspended, and Microgenics shall continue to supply the Assay to the market, until [***]; provided that (i) such period shall not extend beyond an additional [***] ([***]) months from the date of the actual termination of this Agreement, (ii) Achaogen, itself or through or in conjunction with a Third Party, may commercialize another assay for use in conjunction with Plazomicin (i.e., Microgenics shall lose its commercial exclusivity), and (iii) Section 4.2.3 shall be of no force or effect during any such suspended termination.   9.4.5 If this Agreement is terminated during the Term at any time by Achaogen under Section 9.2 (Termination At Will) or by Microgenics under Section 9.3 (Termination for Cause), the following terms shall apply: 9.4.5.1 Solely to the extent the expiration or termination of this Agreement occurs prior to the payment of all development payments described in Section 7.1, Achaogen shall pay to Microgenics an amount equal to the first applicable unpaid development payment as described in Section 7.1 (Development Payments) for the period in which the Agreement is terminated or expires (for illustrative purposes only, if Achaogen provides notice of termination under Section 9.1 (Term) prior to the completion of the Phase 3:  [***], then Achaogen shall pay an amount equal to USD $[***]  to Microgenics pursuant to the terms of Section 7.2 (Invoices; Mechanism of Payment)); provided, that, notwithstanding the foregoing, no payment shall be due under this Section 9.4.5.1 in the event that this Agreement is terminated by Achaogen under Section 9.2 (Termination At Will) at any time in connection with the failure to obtain, or maintain, Regulatory Approval for Plazomicin; and   9.4.5.2 for a period of two (2) years after the expiration or termination date of this Agreement pursuant to Section 9.4.5, in the event Achaogen decides to continue to develop and commercialize Plazomicin, Achaogen shall provide written notice thereof to Microgenics and, upon Achaogen's receipt of a written proposal from Microgenics, the Parties shall use good faith efforts to negotiate a definitive agreement for the continued development, manufacture, supply and sale of the Assay by Microgenics on commercially reasonable terms; provided, however, that nothing in this Section 9.4.5.2 shall (a) obligate Achaogen to enter into any new agreement with Microgenics with respect to the development, manufacture, supply or sale of the Assay or (b) prohibit Achaogen from negotiating or entering into an agreement with any Third Party with respect to the development, manufacture, supply or sale of any assay.

Page 26 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     9.4.6 The termination, expiration or non-renewal of this Agreement shall not relieve either Party from any obligation that accrues pursuant to this Agreement before the effective date of the termination or expiration nor shall it release the Parties from any obligation that may have been incurred as a result of operations conducted under this Agreement.   9.5 Survival. Termination of this Agreement for whatever reason in accordance with the provisions hereof or expiration of this Agreement shall not affect the accrued rights of the Parties, and shall not limit remedies that may be otherwise available in law or equity. Article 1 (Definitions), Section 4.1 (Manufacture), 8 (Intellectual Property Rights; Ownership) (except for Section 8.8 (Trademarks) (unless Achaogen intends to commercialize the Assay upon termination)), 11 (Indemnification), 12 (Confidentiality), and 13 (Miscellaneous) and Section 3.6 (Right of Reference) (but only in the event that Achaogen intends to commercialize the Assay upon termination), 9.4 (Effect of Termination) and 9.5 (Survival) shall survive expiration or termination of this Agreement for any reason. All other rights and obligations will terminate upon expiration of this Agreement.   10 Representations and Warranties   10.1 Representations and Warranties of Each Party. Each of Achaogen and Microgenics hereby represents, warrants and covenants to the other Party hereto as follows:   10.1.1 it is a corporation or other entity duly organized and validly existing under the laws of the state or other jurisdiction of incorporation or formation;   10.1.2 the execution, delivery, and performance of this Agreement by such Party has been duly authorized by all requisite corporate action and does not require any shareholder action or approval;   10.1.3 no consent, approval, order or authorization of, or registration, declaration or filing with, or exemption by, any Third Party or any governmental entity is required by or with respect to such Party in connection with the execution, delivery and performance of this Agreement;   10.1.4 this Agreement constitutes a valid and legally binding obligation of such Party, enforceable against such Party in accordance with its respective terms, except as may be limited by (a) applicable bankruptcy, insolvency, reorganization or other laws of general application relating to or affecting the enforcement of creditors' rights generally and (b) the effect of rules of law governing the availability of equitable remedies;   10.1.5 the execution, delivery and performance of this Agreement do not and will not conflict with, or result in any violation of, or default (with or without notice or lapse of time, or both) under, or give rise to a right of termination, cancellation or acceleration of any obligation that would result in the creation of any encumbrance upon any of the assets owned by such Party under, any material provision of Applicable Law, of such Party's organizational documents or of any agreement, judgment, injunction, order, decree, or other instrument binding on such Party or any assets owned by such Party; and   10.1.6 it shall comply with all material Applicable Laws relating to its activities under this Agreement.   10.2 Representations and Warranties of Microgenics. In addition to the representations and

Page 27 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   warranties made by Microgenics under Section  10.1 (Representations and Warranties of Each Party) above, Microgenics further represents and warrants to Achaogen that:   10.2.1 it has the capacity and resources (including [***]) to (i) develop, manufacture and supply the Assay in and for the Territory, and (ii) commercialize the Assay in the Primary Countries; 10.2.2 and further covenants that, the Assay shall be developed, manufactured, commercialized, and shall function, in accordance with applicable GMP, Specifications and Applicable Laws;   10.2.3 it has the capacity and resources to develop (including [***]), manufacture and commercialize the Assay in accordance with this Agreement, including in accordance with the Project Plan;   10.2.4 to the best of its knowledge, the development, manufacture, use and sale of the Assay will not infringe any issued Patents in the Territory owned or controlled by any Third Party; and   10.2.5 it owns or controls all rights to the Microgenics Cell Lines, Microgenics  [***] Antibodies, and Immunoassay Technologies.   10.3 Representations and Warranties by Achaogen.  In addition to the representations and warranties made by Achaogen under Section 10.1 (Representations and Warranties of Each Party) above, Achaogen further represents and warrants to Microgenics that:   10.3.1 it owns, controls or has the right and ability to grant Microgenics the licenses under its (and its Affiliates) rights in the Achaogen Patents (as listed in Exhibit B hereto) related to the use of Plazomicin, pursuant to this Agreement; and   10.3.2 it owns, controls or has the right and ability to provide to Microgenics the Achaogen Materials for development, manufacture, marketing, and sale of the Assay pursuant to this Agreement.   10.4 Debarment and Exclusion. Achaogen and Microgenics represent and warrant that neither it, nor any of its employees or agents working on the subject matter of this Agreement, has ever been, is currently, or is the subject of a proceeding that could lead to it becoming, as applicable, a Debarred Entity or Debarred Individual, an Excluded Entity or Excluded Individual or a Convicted Entity or Convicted Individual, nor are they listed on the FDA's Disqualified/Restricted List for clinical investigators. Each Party further covenant, represent and warrant that if, during the Term, it, or any of its employees or agents working on their behalf, becomes or is the subject of a proceeding that could lead to that Party with respect to the subject matter hereof, becoming, as applicable, a Debarred Entity or Debarred Individual, an Excluded Entity or Excluded Individual or a Convicted Entity or Convicted Individual, or added to FDA's Disqualified/Restricted List for clinical investigators, the Party shall immediately notify the other Party. This provision shall survive termination or expiration of this Agreement. For purposes of this provision, the following definitions shall apply:   10.4.1 A Debarred Individual is an individual who has been debarred by the FDA pursuant to 21 U.S.C. §335a (a) or (b) from providing services in any capacity to a person that has an approved or pending drug product application.   10.4.2 A Debarred Entity is a corporation, partnership or association that has been debarred by the FDA pursuant to 21 U.S.C. §335a (a) or (b) from submitting or assisting in the submission of

Page 28 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   any abbreviated drug application, or a subsidiary or Affiliate of a Debarred Entity.   10.4.3 An Excluded Individual or Excluded Entity is (a) an individual or entity, as applicable, who has been excluded, debarred, suspended or is otherwise ineligible to participate in federal health care programs such as Medicare or Medicaid by the Office of the Inspector General (OIG/HHS) of the U.S. Department of Health and Human Services, or (b) is an individual or entity, as applicable, who has been excluded, debarred, suspended or is otherwise ineligible to participate in federal procurement and non- procurement programs, including those produced by the U.S. General Services Administration (GSA).   10.4.4 A Convicted Individual or Convicted Entity is an individual or entity, as applicable, who has been convicted of a criminal offense that falls within the ambit of 42 U.S.C. §1320a - 7(a), but has not yet been excluded, debarred, suspended or otherwise declared ineligible.   10.4.5 FDA's Disqualified/Restricted List is the list of clinical investigators restricted from receiving investigational drugs, biologics or devices if the United State Food and Drug Administration (FDA) has determined that the investigators have repeatedly or deliberately failed to comply with regulatory requirements for studies or have submitted false information to the study sponsor.   10.5 Disclaimer. EXCEPT FOR THE EXPRESS REPRESENTATIONS AND WARRANTIES CONTAINED IN THIS AGREEMENT, NEITHER MICROGENICS NOR ACHAOGEN MAKES, AND EACH HEREBY EXPRESSLY DISCLAIMS, ANY REPRESENTATIONS OR WARRANTIES, EITHER EXPRESS OR IMPLIED, WHETHER IN FACT OR IN LAW, INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, OR NON-INFRINGEMENT.   10.6 No Representations Regarding Approval or Commercial Success. Neither Party makes any representations or warranties as to: (a) whether Plazomicin or the Assay will be approved for commercial sale by the applicable Regulatory Authorities; or (b) the commercial potential or success of Plazomicin or the Assay.   11 Indemnification     11.1 Indemnification by Achaogen.  Achaogen shall indemnify, defend and hold harmless Microgenics and its Affiliates and each of its and their respective employees, officers, directors and agents (each a Microgenics Indemnified Party) from and against any and all liabilities, damages, penalties, expenses and/or losses (including reasonable legal expenses and attorneys' fees) (collectively, Losses), resulting from any Third Party suits, claims, actions or demands (collectively, Third Party Claims), to the extent arising out of or relating to: (a) the breach by Achaogen of any representation, warranty or covenant contained in this Agreement; (b) the willful misconduct or negligent acts or omissions of Achaogen, its Affiliates or any of their respective employees, officers, directors or agents; (c) the manufacture, promotion, distribution, use, testing, marketing or sale of pharmaceutical products containing Plazomicin by Achaogen or its Affiliates; or (d) claims of infringement of Third Party Patents based upon the manufacture, use or sale of Plazomicin; except, in each case, to the extent such Losses result from clauses (a), (b), (c) or (d) of Section 11.2 (Indemnification by Microgenics).   11.2 Indemnification by Microgenics.  Microgenics shall indemnify, defend and hold harmless Achaogen and its Affiliates and each of its and their respective employees, officers, directors and agents (each a Achaogen Indemnified Party) from and against any and all Losses, resulting from any Third Party

Page 29 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Claims, to the extent arising out of or relating to: (a) the breach by Microgenics of any representation, warranty or covenant contained in this Agreement; (b) the willful misconduct or negligent acts of Microgenics, its Affiliates or any of their respective employees, officers, directors, or agents; (c) the manufacture, promotion, distribution, use, testing, marketing or sale of the Assay; or (d) claims of infringement of Third Party Patents based upon the manufacture, use or sale of the Assay; except, in each case, to the extent such Losses result from clauses (a), (b) (c) or (d) of Section 11.1 (Indemnification by Achaogen).   11.3 Conditions to Indemnification The obligations of the indemnified Party under Sections 11.1 (Indemnification by Achaogen) and 11.2 (Indemnification by Microgenics) are conditioned upon the delivery of written notice to the indemnifying Party of any potential liability promptly after the indemnified Party become aware of such potential liability; provided, however, that the failure to give such notice promptly shall not impair a Party's right to indemnification under this Section 11.3 (Conditions to Indemnification) unless the delay in providing such notice has a material adverse effect on the ability of the indemnifying Party to defend against such liability. The indemnifying Party shall have the right to assume the defense of any suit or claim relating to the liability if it has assumed responsibility for the suit or claim in writing; however, if in the reasonable judgment of the indemnified Party, such suit or claim involves an issue or matter which could have a material adverse effect on the business operation or assets of the indemnified Party, the indemnified Party may waive its rights to indemnity under this Agreement and control the defense or settlement thereof, but in no event shall any such waiver be construed as a waiver of any rights such indemnified Party may have against any Third Party at law or in equity. If the indemnifying Party defends the suit or claim, the indemnified Party shall cooperate with the indemnifying Party in such defense and the indemnified Party or Parties may participate in (but not control) the defense thereof at its sole cost and expense.   11.4 Settlements. Neither of the Parties may settle a claim or action related to a Third Party Claim without the consent of the other Party, if such settlement would impose any monetary obligation on the other Party, or would require the other Party to submit to an injunction or otherwise limit the other Party's rights under this Agreement. Any payments made by a Party to settle any such claim or action shall be at its own costs and expense, except in the event such payment was made with the prior written consent of an indemnifying Party, in which case such payment shall be subject to the obligations of the Parties as set forth in Sections 11.1 (Indemnification by Achaogen), 11.2 (Indemnification by Microgenics), and 11.3 (Conditions to Indemnification).   11.5 Limitation of Liability. EXCEPT WITH RESPECT TO DAMAGES THAT ARISE DUE TO A  PARTY'S BREACH OF CONFIDENTIALITY (ARTICLE 12) OR  INDEMNIFICATION  OBLIGATIONS  (ARTICLE 11),  IN  NO  EVENT WILL  EITHER  PARTY  BE  LIABLE  TO  THE  OTHER  FOR  CONSEQUENTIAL, INDIRECT,  SPECIAL,  EXEMPLARY OR  PUNITIVE DAMAGES  FOR ANY  CAUSE OF  ACTION, WHETHER  IN  CONTRACT, TORT  OR OTHERWISE,  INCLUDING LOST REVENUES, PROFITS OR BUSINESS OPPORTUNITIES ARISING OUT OF OR  IN CONNECTION WITH THIS AGREEMENT, WHETHER OR NOT THE OTHER  PARTY WAS  OR  SHOULD HAVE  BEEN  AWARE OF  THE POSSIBILITY OF  THESE DAMAGES. EXCEPT WITH  RESPECT TO  DAMAGES THAT  ARISE  DUE TO  A  PARTY'S BREACH  OF  CONFIDENTIALITY  (ARTICLE 12)  OR  INDEMNIFICATION  OBLIGATIONS  (ARTICLE 11), THE  LIABILITY  OF  EITHER  PARTY  UNDER  THIS AGREEMENT  (WHETHER  BY  REASON  OF  BREACH  OF  CONTRACT,  TORT,  OR  OTHERWISE)  WITH  RESPECT  TO  A  GIVEN  CLAIM  SHALL  NOT  EXCEED  AN AMOUNT EQUAL TO [***].   11.6 Insurance.  Each Party shall maintain, through self-insurance or commercially-placed insurance, adequate commercial general liability and products liability insurance, including contractual liability coverage, necessary to satisfy its obligations hereunder and consistent with pharmaceutical and

Page 30 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   diagnostic industry practices.   12 Confidentiality   12.1 Nondisclosure. During the Term, and for a period of [***] ([***]) years thereafter, all Confidential Information disclosed to a Party hereto or its Affiliates (the Receiving Party) by the other Party or its Affiliates (the Disclosing Party) shall be deemed confidential and shall be treated as such by the Receiving Party (meaning that the Receiving Party shall take the same steps to protect such information as it does to protect its own confidential information, which in any event shall be no less than the reasonable protective measures for the industry) and shall only be used for the purposes of this Agreement. Notwithstanding the foregoing, Confidential Information shall not include information that is:     (a) known by the Receiving Party at the time of its receipt and not through a prior disclosure by the Disclosing Party;     (b) at the time of disclosure or thereafter, becomes published or otherwise part of the public domain through no breach of this Agreement by the Receiving Party;     (c) subsequently disclosed to the Receiving Party by a Third Party having the right to make such a disclosure; or     (d) developed by the Receiving Party, as evidenced by its records, independently of information received by it from the Disclosing Party hereunder.   12.2 Permitted Disclosure.  Information provided under this Agreement may be disclosed to employees, agents or consultants of the Receiving Party, but only to the extent required to accomplish the purposes of this Agreement and only after the Receiving Party obtains the prior agreement of its employees, agents and consultants to whom disclosure is to be made to hold in confidence and not to make use of such information for any purpose other than that permitted by this Agreement. In addition to the foregoing exceptions, either Party may disclose Confidential Information to the extent it is required to be disclosed under Applicable Law, or in connection with any application by the Receiving Party for any Regulatory Approvals; provided, however, that the Receiving Party shall furnish the Disclosing Party with as much prior written notice of such disclosure requirement as reasonably practicable, so as to permit the Disclosing Party, in its sole discretion, and at its sole expense, to take appropriate action, including seeking a protective order, in order to prevent the Disclosing Party's Confidential Information from passing into the public domain or becoming generally available to the public.   12.3 Publicity. The Parties agree to make a joint public release of the having entered into this Agreement upon the successful completion of Phase I as described in Exhibit F. The public release must however not contain any Confidential Information of any kind such as scientific, commercial or financial which both Parties have not agreed to include in writing. No public announcement concerning the existence, terms or subject matter of this Agreement shall be made, either directly or indirectly, by any Party, without first obtaining the prior written approval of the other Party and agreement upon the nature and text of such public announcement which such agreement and approval shall not be unreasonably withheld. Notwithstanding the foregoing, if, in the opinion of legal counsel for the Party desiring to make such public announcement, such disclosure is required under Applicable Law, subject to Section 12.2 (Permitted Disclosure) above, the Party required to make such public announcement shall inform the other Parties of the proposed announcement or disclosure in reasonably sufficient time prior to public release, which shall be not

Page 31 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   less than [***]  ([***]) business days (or such shorter period as may be required under Applicable Law) prior to release of such proposed public announcement, and shall provide the other Parties with a written copy thereof in order to allow such other Parties to comment upon such public announcement. The Receiving Party shall reasonably cooperate with the Disclosing Party (at the Disclosing Party's expense) with respect to all disclosures regarding this Agreement required under Applicable Law, including requests for confidential treatment of proprietary information of the Disclosing Party included in any such disclosure.    12.4 Applicable Law. Nothing in this Agreement shall be construed as preventing or in any way inhibiting any Party from complying with Applicable Law governing activities and obligations undertaken pursuant to this Agreement, in any manner which it reasonably deems appropriate, including, for example, by disclosing to Regulatory Authorities confidential or other information received from the other Parties, subject to Sections 12.2 (Permitted Disclosure) and 12.3 (Publicity).   12.5 Non-Use of Names. Except as otherwise provided in this Agreement, neither Party (or its Affiliates) shall use, either directly or indirectly, the Trademarks of the other Party (or their Affiliates), or the names of any of their officers, employees or board members in any publicity, marketing advertising or other documents (or other disclosures) unless (a) such use is consistent with, and permitted under, the Project Plan or (b) a copy or transcript of the proposed disclosure is submitted to and approved in advance in writing by the other Party (each in its sole discretion), except in the case in which a governmental authority requires the use of the Trademark by a Party in the sale or distribution of the Assay or Plazomicin. Each Party will use good faith efforts to review and approve any proposed disclosure within [***] ([***]) business days of its receipt from the other Party of a copy or transcript of the proposed disclosure. If a Party approves the other Party's usage of its Trademarks (or its Affiliates), or the names of any of their officers, employees or board members in accordance with this Section 12.5 (Non-Use of Names), the other Party shall comply with any usage guidelines or requirements imposed by the approving Party.   12.6 Publications. Publication in a journal, paper, magazine or any other such similar disclosure relating to the development, manufacture or commercialization of the Assay will not take place without the prior written agreement of both Achaogen and Microgenics, which shall not be unreasonably withheld. Any draft article intended to be submitted for publication by Microgenics or Achaogen (or a clinical trial site utilized by Achaogen) hereto shall first be sent to the other Party in order to allow such Party to preserve its intellectual property rights by delaying such publication (but not for more than  [***] ([***]) days) and/or removing its Confidential Information. Achaogen's and/or Microgenics' contribution shall be acknowledged in any publication by co-authorship or acknowledgment, whichever is appropriate. Republication of any article, in whole or in part, which has previously been approved by the Parties shall not require subsequent approval, provided that the content is substantially unchanged. These restrictions are not applicable to Plazomicin; provided, however, that, for clarity, Microgenics shall have no right to publish with respect to Plazomicin.   12.7 Prior CDAs. This Agreement supersedes that certain Confidential Disclosure Agreement between the Parties dated  [***]; provided, however, that all Confidential Information disclosed or received by the Parties thereunder will be deemed Confidential Information hereunder and will be subject to the terms and conditions of this Agreement. For clarity, this Agreement does not supersede the Antibody Development Agreement.   13 Miscellaneous   13.1 Force Majeure. Neither Party shall be liable to the other for delay or failure in the

Page 32 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   performance of the obligations on its part contained in this Agreement if and to the extent that such failure or delay is due to government action, war, terrorism, fire, explosion, flood, strike, lockout, embargo, shortage of materials or utilities, vendor failure to supply, act of God, or any other cause beyond the control and without the fault or negligence of the defaulting Party (a Force Majeure Event), provided that the Party claiming Force Majeure Event has exerted all Commercially Reasonable Efforts to avoid or remedy such force majeure. Such excuse shall continue as long as the condition preventing the performance continues. Upon cessation of such Force Majeure Event, the affected Party shall promptly resume performance hereunder. Each Party agrees to give the other Party prompt written notice of the occurrence of any such Force Majeure Event, the nature thereof, and the extent to which the affected Party will be unable to perform its obligations hereunder. Each Party further agrees to use all Commercially Reasonable Efforts to correct the Force Majeure Event  [***] and to give the other Party prompt written notice when it is again fully able to perform its obligations hereunder.   13.2 Assignment. Neither Party may assign this Agreement to a Third Party unless both Parties have agreed to such assignment in a writing signed by an authorized representative of each Party hereto; provided, however, that upon providing written notice, (i) either Party may, without the other Party's consent, assign this Agreement to an Affiliate or to any Third Party entity that acquires all or substantially all of its assets to which this Agreement relates and (ii) Achaogen may, without Microgenics' consent, assign this Agreement (in whole or in part) to a Third Party licensee of Achaogen's rights with respect to Plazomicin. This Agreement shall be binding upon and inure to the benefit of the successors and permitted assigns of the Parties. Any assignment not in accordance with this Section 13.2 (Assignment) shall be void.   13.3 No Waiver. The failure of either Party to require performance by the other Party of any of that other Party's obligations hereunder shall in no manner affect the right of such Party to enforce the same at a later time. No waiver by any Party hereto of any condition, or the breach of any provision, term, representation or warranty contained in this Agreement, whether by conduct or otherwise, in any one or more instances, shall be deemed to be or construed as a further or continuing waiver of any such condition or breach, or of any other condition or of the breach of any other provision, term, representation or warranty hereof.   13.4 Severability.  If a court or other tribunal of competent jurisdiction should hold any term or provision of this Agreement to be excessive, or invalid, void or unenforceable, the offending term or provision shall be deleted, and, if possible, replaced by a term or provision which, so far as practicable, achieves the legitimate aims of the Parties. In the event that such provisions cannot be agreed upon, the invalidity, illegality or unenforceability of one or more provision of this Agreement shall not affect the validity of this Agreement as a whole.   13.5 Relationship Between the Parties. Both Parties are independent contractors under this Agreement. Nothing herein contained shall be deemed to create an employment, agency, joint venture or partnership relationship between the Parties hereto or any of their agents or employees, or any other legal arrangement that would impose liability upon one Party for the act or failure to act of the other Party. Neither Party shall have any express or implied power to enter into any contracts or commitments or to incur any liabilities in the name of, or on behalf of, the other Party, or to bind the other Party in any respect whatsoever.

Page 33 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   13.6 Correspondence and Notices. Correspondence, reports, documentation and any other communication in writing between the Parties in the course of implementation of this Agreement shall be in writing and sent by internationally recognized overnight delivery service that maintains records of delivery, or by facsimile confirmed by prepaid registered or certified air mail letter, and shall be deemed to have been properly served to the addressee upon the date delivered by hand or transmitted by facsimile (with transmission confirmed) or on the second business day (at the place of delivery) after deposit with an internationally recognized overnight delivery service. The proper address for communication and for all payments shall be:   To Microgenics: With a copy to:   Microgenics Corporation Thermo Fisher Scientific Attn: VP & General Manager Attn: SDG General Counsel 46500 Kato Road 81 Wyman Street Fremont, CA 94538 Waltham, MA 02451 Fax: Fax: (781) 622-1283     To Achaogen: With a copy to:     Achaogen Inc.   7000 Shoreline Court, #371   South San Francisco, CA 94080   Fax:     13.7 Choice of Law.  This Agreement is subject to and governed by the laws of the State of Delaware, U.S.A. (without regard to conflict of law principles).   13.8 Dispute Resolution.    13.8.1 Executive Resolution. In the event of a dispute with respect to (a) the validity, interpretation or construction of this Agreement, (b) compliance with this Agreement or (c) a breach of this Agreement (a Dispute), a Party may provide the other Party with written notice of the Dispute, and the Parties agree to exercise reasonable efforts to resolve the Dispute in good faith by promptly engaging in discussions with duly authorized representatives of the Parties. If the Dispute cannot be resolved by such authorized representatives of the Parties within [***] ([***]) business days, the authorized representatives shall refer the Dispute to a meeting between a senior executive representing each Party (currently the [***] for Achaogen, and the [***] for Microgenics), which such senior executives shall participate in at least one in person meeting as soon as practicable, but in no event later than [***] ([***]) days after the date of the relevant referral. If the senior executives for Achaogen and Microgenics cannot resolve such Dispute in a mutually acceptable manner within [***] ([***]) business days after such meeting, then the Dispute shall be resolved exclusively by final and binding arbitration in accordance with Section 13.8.2.    13.8.2 Arbitration. Arbitration will be conducted exclusively in the State of Delaware by arbitration administered by the American Arbitration Association (AAA) under its Commercial Arbitration Rules and Supplementary Procedures for Large Complex Disputes, and judgment on the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof. [***]. Notwithstanding anything in this Agreement to the contrary, each Party shall have the right, at its election, to seek injunctive or other equitable relief in any court of competent jurisdiction to enforce or obtain compliance with any provision of

Page 34 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   this Agreement without first submitting such matter to arbitration. All rights and remedies hereunder shall be cumulative, may be exercised singularly or concurrently and, unless otherwise stated herein, shall not be deemed exclusive.    13.9 Entire Agreement; Amendment. Except as otherwise set forth in Section 12.7, this Agreement and the Antibody Development Agreement, including the Exhibits and Schedules hereto and thereto and all the covenants, promises, agreements, warranties, representations, conditions and understandings contained herein and therein sets forth the complete, final and exclusive agreement between the Parties and supersedes and terminates all prior and contemporaneous agreements and understandings between the Parties, whether oral or in writing. There are no covenants, promises, agreements, warranties, representations, conditions or understandings, either oral or written, between the Parties other than as are set forth in this Agreement and the Antibody Development Agreement. No subsequent alteration, amendment, change, waiver or addition to this Agreement shall be binding upon the Parties unless reduced to writing and signed by an authorized officer of each Party. No understanding, agreement, representation or promise, not explicitly set forth herein, or in the Antibody Development Agreement, has been relied on by either Party in deciding to execute this Agreement. Notwithstanding anything to the contrary contained herein or in the Antibody Development Agreement, nothing in the Antibody Development Agreement shall be deemed to modify or diminish the representations, warranties, covenants and obligations of the Parties under this Agreement and in the event of any conflict between the terms and conditions of this Agreement and the terms and conditions of the Antibody Development Agreement, this Agreement shall govern except with respect to Section 4.2.7.3 of this Agreement which shall be subject to the Antibody Development Agreement.   13.10 Headings. The headings and captions used in this Agreement are solely for the convenience of reference and shall not affect its interpretation.   13.11 Counterpart. This Agreement may be executed in one or more counterparts, each of which shall be an original, and all of which shall constitute together the same document. Each Party acknowledges that an original signature or a copy thereof transmitted by facsimile (or .pdf file) shall constitute an original signature for purposes of this Agreement.   13.12 Further Actions. Each Party agrees to execute, acknowledge and deliver such further instruments, and to do all other acts, as may be necessary or appropriate in order to carry out the purposes and intent of this Agreement including any filings with any antitrust agency which may be required.   13.13 Affiliates. Both Parties shall have the right, in their sole discretion, to perform some or all of its obligations and exercise some or all of its rights under this Agreement through its Affiliates.   13.14 Joint Negotiation. This Agreement is the joint product of Microgenics and Achaogen, and each provision hereof has been subject to the mutual consultation, negotiation and agreement of the Parties and their respective legal counsel and advisers and any rule of construction that a document shall be interpreted or construed against the drafting Party shall not be applicable.   13.15 Construction. Except where the context otherwise requires, wherever used, the singular shall include the plural, the plural the singular, the use of any gender shall be applicable to all genders and the word or is used in the inclusive sense (and/or). All references to a business day or business days in this Agreement means any day other than a day which is a Saturday, a Sunday or any day banks are authorized or required to be closed in the United States. The words include, includes and including shall be deemed to be followed by the phrase without limitation. The word will shall be construed to have the same

Page 35 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   meaning and effect as the word shall. The words herein, hereof and hereunder, and words of similar import, shall be construed to refer to this Agreement in its entirety and not to any particular provision hereof. All currency herein shall refer to United States dollars, unless specifically provided otherwise. All exhibits to this Agreement are hereby made a part of this Agreement.   13.16 Use of Third Parties. All obligations under this Agreement shall be performed by the Party designated to perform such obligations under this Agreement and such obligations may not be performed by a Third Party on such Party's behalf, unless (a) the other Party has consented in writing which shall not be unreasonably be withheld or delayed, (b) the Party engaging such Third Party performs appropriate qualification and oversight of such Third Party in accordance with the Applicable Law, including applicable GMP, GCP, and GLP requirements, and (c) the Party engaging such Third Party ensures that such Third Party complies with the terms and conditions of this Agreement, and provided that such performance of activities by a Third Party is consistent with the rights and obligations of the Parties under this Agreement. Notwithstanding any such consent, each Party shall remain at all times fully liable for its respective responsibilities under this Agreement. Each Party hereby expressly waives any requirement that the other Party exhaust any right, power or remedy, or proceed against such subcontractor for an  obligation or performance hereunder, prior to proceeding directly against the Party engaging such subcontractor.     [Signature Page to Follow]

Page 36 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.     IN WITNESS WHEREOF, duly authorized representatives of the Parties have duly executed this Agreement to be effective as of the Effective Date.       ACHAOGEN INC. MICROGENICS CORPORATION   By: /s/ Blake Wise By: /s/ Marc Tremblay

Name: Blake Wise Name: Marc Tremblay

Title: COO Title: President, Clinical Diagnostics

Date: 4/26/16 Date: 4/26/2016



Signature Page to Collaborative Development and Commercialization Agreement DB2/ 26356633.19

[***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Exhibit A Achaogen Materials

Achaogen Materials Estimated Amount Estimated Development PhaseRequired [***]

    (1) [***]

Page 38 of 60 DB2/ 26356633.19

[***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Exhibit B Achaogen Patents [***]



Page 39 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions. DB2/ 26356633.19





Confidential Treatment Requested by Achaogen, Inc.   Exhibit C Microgenics' Cell Lines   [***]

Clone # Clone ID

[***]     [***]

Clone # Clone ID

[***]   [***]

Clone # Clone ID

[***]

    [***] Rabbit Identity Immunogen [***]   [***]

Page 40 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions. DB2/ 26356633.19





Exhibit D Plazomicin Chemical Structure





Page 41 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Confidential Treatment Requested by Achaogen, Inc.   Exhibit E Primary Countries   Achaogen Primary Country List Country Country [***]

Page 42 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions. DB2/ 26356633.19





Confidential Treatment Requested by Achaogen, Inc.   Exhibit F Project Plan Timeline and Deliverables     Plazomicin TDM Immunoassay Development Project Plan Timeline and Deliverables   Deliverables Start End Duration (M) Phase 0 [***] [***] [***] [***] [***] [***] Phase 1 [***]  [***] [***] [***] •[***] •[***] Phase 2 [***] [***] [***] [***] [***] [***] Phase 3 [***] [***] [***] [***] [***] [***] [***] [***] Phase 4 [***] [***] [***] [***] Milestone 1: [***] [***] [***] [***] [***] Milestone 2: [***] [***] [***] [***] [***] Milestone 3: [***] [***] [***] [***] Milestone 3A: [***] [***] [***] [***] [***] Milestone 3B: [***] [***] [***] [***] [***] [***] [***] [***] [***] [***] [***] Phase 5 [***] [***] [***] [***] Milestone 1: [***] [***] [***] [***] [***] Milestone 2: [***] [***] [***] [***] [***]

Page 43 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions. DB2/ 26356633.19





Confidential Treatment Requested by Achaogen, Inc.   Exhibit G Specifications   [***]   Performance Attributes Desired Value(s) Acceptable Value(s)

[***]

    1 [***]

Page 44 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions. DB2/ 26356633.19





Confidential Treatment Requested by Achaogen, Inc.   Exhibit H - BARDA Requirements

1.0 Additional Terms and Conditions for this Agreement as a Federal Subcontract

  1.1 Purpose. This Agreement is a subcontract under the following Achaogen Government Contract(s):

  •  Contract No. HHSO100201000046C (BARDA 0046C Contract) between Achaogen, Inc. and Department of Health and Human Services, Biomedical Advanced Research and Development Authority;

The purpose of this Section 1.0 is to incorporate by reference certain government ( Government) contract clauses (flow downs) associated with the Achaogen Government Contract(s) specified above, that Achaogen, as a prime contractor, must include, and by which Microgenics, as a subcontractor, must abide.

  1.2 Incorporated Government Contract Clauses

  (a) For BARDA Contract. This Agreement incorporates by reference Appendix A, Government Provisions for Commercial Item Subcontracts Under Contract No. HHSO100201000046C (BARDA 0046C Contract). Microgenics agrees to abide by all of the provisions listed in Appendix A hereto as a condition of performance of services pursuant to any duly-executed Exhibit under this Agreement.

  1.3 Changes to Government Contracts Provisions

Microgenics agrees that upon the request of Achaogen it will negotiate in good faith with Achaogen amendments to this Agreement to incorporate additional provisions herein or to change provisions hereof, as Achaogen may reasonably deem necessary in order to comply with the provisions of the applicable Achaogen Government Contract or with the provisions of amendment(s) to such Achaogen Government Contract. If any such amendment to this Agreement causes [***], an equitable adjustment shall be made pursuant to the Changes clause of this Agreement.

  1.4 RESERVED [Not applicable]

  1.5 Government Right to Inspection of Research and Development (Reference: FAR 52.246-9)

  (a) Microgenics recognizes that the Government has the right to inspect and evaluate work performed or being performed under the Achaogen Government Contract, including any such work performed or being performed under this Agreement, to the extent practicable at all reasonable places and times and in a manner that will not unduly delay the work, including the period of performance, and in any event before its termination.

  (b) If the Government performs any inspection or test on Microgenics' premises, Microgenics shall furnish all reasonable facilities and assistance for the safe and convenient performance of these duties.

  1.6 Representations and Certifications

Page 45 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions. DB2/ 26356633.19





By executing this Agreement, Microgenics represents and certifies that:

  (a) neither it, nor any of its Principals (as defined hereinafter), is presently debarred, suspended, proposed for debarment or otherwise declared ineligible for participating in any federal or state procurement action by any federal, state, or local government or agency;

  (b) neither it, nor any of its Principals, has within the last three years, been convicted of, or had a civil judgment rendered against it, for any of the following: (i) the commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a federal, state or local government contract or agreement; (ii) a violation of federal or state antitrust statutes relating to the submission of offers; or (iii) the commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, or receiving stolen property;

  (c) it will comply with all applicable Federal laws and regulations regarding ethics in public acquisitions and procurement and performance of contracts;

  (d) RESERVED

  (e) it has not made or solicited and will not make or solicit kickbacks in violation of FAR 52.203-7 or the Anti- Kickback Act of 1986 (41 USC 51-58);

  (f) that (i) no federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with the awarding of this Agreement; (ii) if any funds other than federal appropriated funds (including profit or fee received under a covered federal transaction) have been paid, or will be paid, to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress on his or her behalf in connection with this Agreement, Microgenics shall complete and submit, with its offer, OMB standard form LLL, Disclosure of Lobbying Activities, to the Contracting Officer; and (iii) it will include the language of this certification in all subcontract awards at any tier and require that all recipients of subcontract awards in excess of $150,000 shall certify and disclose accordingly (the definitions and prohibitions contained in the clause at FAR 52.203- 12, Limitation on Payments to Influence Certain Federal Transactions, included in this Subsection 12.7 (f) and will be included in all such certifications);

  (g) that (i) if Microgenics has participated in a previous contract or subcontract subject to the Equal Opportunity clause (FAR 52.222-26), Microgenics has filed all required compliance reports; and (ii) representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards; and

  (h) that to the best of the Microgenics's knowledge and belief, there are no relevant facts or circumstances which could give rise to an organizational conflict of interest, as defined in FAR Subpart 9.5.

Microgenics agrees to provide immediate written notice to Achaogen if, at any time prior to termination, Microgenics learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances. For the purpose of paragraphs (a)

Page 46 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





and (b) above, Principal means an officer; director, owner; partner; or a person having primary management or supervisory responsibilities within a business entity.



2.0 Government Interface

  2.1 Microgenics employees may not communicate with any Government employee, including Achaogen's contracting officer (Contracting Officer), Contracting Officer's representative or their respective support staff, concerning any work performed pursuant to this Agreement or any associated Exhibit or appendix, without advance written consent from Achaogen.

  2.2 Under no circumstances may Microgenics accept Government instruction on behalf of Achaogen. Microgenics is not authorized to make offers, commitments, or otherwise negotiate with the Government on Achaogen's behalf or its own behalf in its capacity as a subcontractor to Achaogen. In case of occurrence of any such events, Microgenics shall:

  (a) suggest to the Government representative that Achaogen be involved in all such discussions, and

  (b) immediately report to Achaogen any attempt by Government personnel to provide such instruction or conduct such negotiations.

  2.3 If Microgenics communicates with the Government regarding a Project, Microgenics's monthly contract management reports shall list all data exchanged and shall summarize each and every significant discussion with Government personnel during the reporting period.

3.0 Disputes

  3.1 Disputes Involving the Prime Contract and/or the Government

  (a) Any dispute arising under or related to this Agreement which relates to a matter for which Achaogen has recourse against the Government under the Achaogen Government Contract (also hereinafter sometimes referred to as the Prime Contract) shall be resolved as follows unless the Parties otherwise agree in writing.

  (b) Microgenics shall give Achaogen a fully supported written request for equitable adjustment or claim concerning any such dispute within [***] years after the basis of the equitable adjustment arises or claim accrues, but in no event later than [***], or Microgenics shall be barred from any remedy for such claim.

  (c) Achaogen shall forward such request for equitable adjustment or claim to the Contracting Officer on Microgenics's behalf for final decision, subject to the limitations and other conditions contained in this provision. Achaogen shall in good faith consult with Microgenics concerning the forwarding of such request for equitable adjustment or claim to the Contracting Officer.

  (d) Any final decision of the Contracting Officer under the Prime Contract as it relates to this Agreement, whether or not it results from a claim under Section 3.1(b) and (c) of this Agreement submitted on Microgenics's behalf under the provision stated above, shall be binding upon Microgenics; provided however, that Achaogen shall notify Microgenics immediately of any such final decision of the Contracting Officer and if: (i) Achaogen elects not to appeal such decision pursuant to the

Page 47 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





  Disputes clause of the Prime Contract; (ii) Achaogen thereafter receives, no less than [***] ([***]) days before the expiration of the period of appeal under the Disputes clause of the Prime Contract, a written request by Microgenics to appeal such decision, and (iii) Achaogen has the right of such appeal under the Prime Contract, then Achaogen shall file an appeal from the final decision on Microgenics's behalf.

  (e) If Achaogen appeals such a decision, whether at its election or at Microgenics's request, any decision upon such appeal by the Board of Contract Appeals, the United States Court of Federal Claims, or any other board or agency having jurisdiction over the appeal shall be binding upon Microgenics insofar as it relates to a claim under this Section 3.1 of this Agreement, provided however, that if Microgenics timely (i.e., no less than [***] ([***]) days before the expiration of the relevant period of appeal) requests Achaogen to bring a further appeal to obtain judicial review of such final decision by a court of competent jurisdiction, Achaogen shall do so, subject to the terms below. A final judgment in any such further appeal, if binding on Achaogen under the Prime Contract, shall in turn be binding on Microgenics insofar as it relates to a claim under this Section 3.1 of this Agreement.

  (f) In any appeal brought by Achaogen on behalf of Microgenics, or at Microgenics's request under the above provisions, [***] shall bear all costs and expenses incurred by Microgenics in prosecuting such appeal, including but not limited to, any legal fees or costs incurred. In any appeal taken or brought by Achaogen, whether at its election or at Microgenics request, Microgenics shall cooperate fully with Achaogen in its prosecution thereof in every reasonable manner and Microgenics shall be afforded reasonable opportunity to participate in the prosecution thereof to the extent Microgenics's interest may be affected. To the extent requested by Achaogen, Microgenics shall prosecute for Achaogen any appeal taken or brought at Microgenics request and, in such event, Achaogen shall assist Microgenics in every reasonable manner.

  (g) If Achaogen is required to certify any claim of Microgenics, Achaogen shall not forward such claim unless it is reasonably satisfied the claim is in good faith, and Achaogen can certify such claim to the Contracting Officer to the extent and manner required by the Contract Disputes Act, as applicable. Microgenics agrees to provide Achaogen with such information as Achaogen reasonably may deem necessary to make this determination, including but not limited to, its own certification in the form prescribed by the Contract Disputes Act or its implementing regulations. Such certification shall be executed by a person duly authorized to bind Microgenics. Microgenics agrees that, with respect to any claim or dispute that arises under or relates to the Prime Contract which, if it were Achaogen's claim, can properly be submitted for a decision of the Contracting Officer under the Disputes clause, its right of claim or appeal is limited to the procedures set forth in this provision.

  (h) Microgenics's failure to comply with the terms of this provision shall entitle Achaogen to terminate any such appeal on Microgenics's behalf. The rights and obligations described herein shall survive completion of and final payment under this Disputes section.

  3.2 Other Disputes Any dispute arising under or related to this Agreement which relates to a matter for which Achaogen has recourse against the Government under the Prime Contract shall be resolved in accordance with Subsection 3.1. In the event of any dispute between the

Page 48 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





  Parties arising out of or in connection with this Agreement that does not relate to a matter for which Sponsor has recourse against the Government under the Prime Contract, such dispute shall be resolved pursuant to Section 13.8 of the Agreement.

  3.3 Choice of Law: This Agreement is subject to and governed by the laws of the State of Delaware, U.S.A. without regard to conflict of law principles, as applicable except that any provision in this Agreement that is (i) incorporated in full text or by reference from the Federal Acquisition Regulation (FAR) or (ii) incorporated in full text or by reference from any agency regulation that implements or supplements the FAR or (iii) substantially based on any such FAR provision or agency regulation, shall be construed and interpreted according to the federal common law of government contracts as enunciated and applied by federal judicial bodies, boards of contract appeals, and quasi- judicial agencies of the federal government.

Page 49 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





APPENDIX A Government Provisions for Commercial Item Subcontracts  Under Contract Number HHSO100201000046C (BARDA Prime Contract)

The following provisions, as they may be amended by the United States Government over time, are incorporated by reference with the same force and effect as if set forth in full text and shall be deemed to apply solely to such portions of work as are funded using Government funds. For the purposes of this Agreement, the term contract shall mean this Agreement; the terms Contractor and Company shall mean Microgenics; the term prime contractor shall mean Achaogen; and the terms Government and Contracting Officer may mean Achaogen or the United States Government as expressly indicated on this document. The dollar amount listed parenthetically in the titles of some referenced clauses in this Appendix A is the applicability threshold for the clause. If the total cumulative amount invoiced by Microgenics for all Government Sponsored Projects performed under the BARDA Prime Contract is expected to exceed this amount, the clause applies.

FEDERAL ACQUISITION REGULATION

Clause Date Title FAR 52.202-1 Jul-04 Definitions (Over $100,000) FAR 52.203-3 Apr-84 Gratuities (Over $100,000) FAR 52.203-5 Apr-84 Covenant Against Contingent Fees (Over $100,000). Substitute Achaogen  for Government or United States in paragraph (a) of this clause, provided however that Achaogen may annul the contract or deduct amounts only to the extent of a Government annulment or deduction due to conduct of Microgenics. FAR 52.203-6 Sep-06 Restrictions on Subcontractor Sales to the Government (Over $100,000) FAR 52.203-7 Jul-95 Anti-Kickback Procedures (Over $100,000) FAR 52.203-8 Jan-97 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (Over $100,000). Substitute Achaogen  for Government or United States throughout this clause, provided however that Achaogen may rescind the contract and recover funds only to the extent of a Government rescission or recovery due to conduct of Microgenics. FAR 52.203-10 Jan-97 Price or Fee Adjustment for Illegal or Improper Activity (Over $100,000) Substitute Achaogen  for Government or United States throughout this clause and Achaogen for Contracting Officer throughout this clause, provided however that Achaogen may make a reduction only to the extent that the Government makes a reduction due to conduct of Microgenics. FAR 52.203-12 Sep-07 Limitation on Payments to Influence Certain Federal Transactions (Over $100,000) FAR 52.203-13 Apr-10 Contractor Code of Business Ethics and Conduct (applies if Agreement is over $5,000,000 and has a performance period greater than 120 days). Disclosures made under this clause shall be made directly to the government entities listed in the clause. FAR 52.203-14 Dec-07 Display of Hotline Poster(s). (d) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed $5,000,000, except when the subcontract-(1) Is for the acquisition of a commercial item; or (2) Is performed entirely outside the United States.

Page 50 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Clause Date Title FAR 52.209-6 Sep-06 Protecting the Government's Interests When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment (Over $30,000) FAR 52.215-2 Mar 09 Audit and Records- Negotiation (Over $100,000) (Only Government receives access and audit rights under this clause) FAR 52.215-21 Oct-97 Requirements for Cost or Pricing Data or Information Other Than Cost or Pricing Data-Modifications. Substitute Achaogen for Contracting Officer throughout this clause, provided however, that Achaogen may seek from Microgenics only such information as the Government has requested, and Microgenics shall deliver any such information directly and only to the Government. FAR 52.215-21 (as modified above) shall apply only with respect to modifications funded by the Government; FAR 52.215-21 shall not apply to modifications that are not funded by the Government. FAR 52.219-8 May-04 Utilization of Small Business Concerns (Over $100,000) FAR 52.222-3 Jun-03 Convict Labor FAR 52.222-21 Feb-99 Prohibition of Segregated Facilities FAR 52.222-26 Mar-07 Equal Opportunity (Over $10,000) FAR 52.222-35 Sept-06 Equal Opportunity for Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Over $100,000) FAR 52.222-36 Jun-98 Affirmative Action for Workers with Disabilities (Over $10,000) FAR 52.222-37 Sep-06 Employment Reports on Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans (Over $100,000) FAR 52.222-39 Dec-04 Notification of Employee Rights Concerning Payment of Union Dues or Fees. Applicable if value of this Agreement equals or exceeds $100,000. FAR 52.222-50 Feb-09 Combating Trafficking in Persons FAR 52.222-54 Jan-09 Employment Eligibility Verification. Applicable to services and construction subcontracts that: (1) exceed $3,000; and (2) include work performed in the United States. This clause does not apply to subcontracts for commercial services that are (a) part of the purchase of a Commercially Available Off the Shelf (COTS) item (or an item that would be a COTS item, but for minor modifications) (b) performed by the COTS provider, and (c) are normally provided for that COTS item. FAR 52.223-6 May-01 Drug-Free Workplace FAR 52.224-1 Apr-84 Privacy Act Notification (If subcontract requires design, development, or operation of a system of records) FAR 52.224-2 Apr-84 Privacy Act (If subcontract requires design, development, or operation of a system of records) FAR 52.225-1 Feb-09 Buy American Act- Supplies FAR 52.225-13 Jun-08 Restrictions on Certain Foreign Purchases FAR 52.227-1 Dec-07 Authorization and Consent, Alternate I (Apr 1984) (Over $100,000) FAR 52.227-2 Dec-07 Notice and Assistance Regarding Patent and Copyright Infringement (Over $100,000). Substitute Achaogen for Contracting Officer throughout this clause. Insert or Achaogen after Government throughout this clause.

Page 51 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Clause Date Title FAR 52.227-11 Dec-07 Patent Rights -Ownership by the Contractor (Only Government receives license; Achaogen receives no license.) (Note: In accordance with FAR 27.303(b)(2), paragraph (e) is modified to include the requirements in FAR 27.303(b)(2)(i) through (iv). The frequency of reporting in (i) is annual. Microgenics shall provide to Achaogen a copy of any notice or election that Microgenics submits to the Contracting Officer pursuant to subparagraph (c)(1), (c)(2) and (e)(3). FAR 52.227-16 Jun-87 Additional Data Requirements. Substitute Achaogen for Contracting Officer throughout this clause, provided however, that Achaogen may order from Microgenics only such data that the Government has ordered and provided further that the following data are hereby specifically identified for purposes of FAR 52.227-16(b), and are not subject to disclosure obligations under FAR 52.227-16, and shall not be disclosed: (i) Immunoassay Technologies (as defined in Section 1.16); (ii) Microgenics Know-How (as defined in Section 1.18) related to Immunoassay Technologies; and (iii) any and all limited rights data (i.e., data that embody trade secrets or are commercial or financial and confidential or privileged, to the extent such data pertain to items, components, or processes developed at private expense, including minor modifications) not already included in (i) or (ii). FAR 52.242-15 Aug-89 Stop Work Order (April 1984) (Achaogen may issue stop work order only to the extent the Government issues a stop work order) Substitute Achaogen for Contracting Officer throughout this clause. FAR 52.244-5 Dec-96 Competition in Subcontracting FAR 52.244-6 Jun-10 Subcontracts for Commercial Items FAR 52.245-1 Aug-10 Government Property Applicable where government property involved in performance of subcontract; Contracting Officer means Achaogen except in the definition of Property Administrator and in paragraph h(1)(iii) and where it is unchanged, and in paragraphs (c) and (h)(4) where it includes Achaogen. Government is unchanged in the phrases Government property and Government furnished property and where elsewhere used except in paragraph (d)(1) where it means Achaogen and except in paragraphs (d)(2) and (g) where the term includes Achaogen.

THE DEPARTMENT OF HEALTH AND HUMAN SERVICES SUPPLEMENTAL REGULATION PROVISIONS

Clause Date Title HHSAR 352.203-70 Jan-06 Anti-lobbying HHSAR 352.223-70 Jan-06 Safety and Health HHSAR 352.224-70 Jan-06 Privacy Act (if subcontract requires design, development, or operation of a system of records) HHSAR 325.242-73 Jan-06 Withholding of Contract Payments HHSAR 352.270-4 Jan-06 Protection of Human Subjects HHSAR 352.270-5 Jan-06 Care of Live Vertebrate Animals HHSAR 352.270-6 Jan-06 Restriction on Use of Human Subjects

Page 52 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





HHSAR 352.227-70 Jan-06 Publications and Publicity

Page 53 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





BARDA REQUIRED PROVISIONS

Prime Contract Provision

Clause

H.2: Human Materials The acquisition and supply of all human specimen material (including fetal material) used under this contract shall be obtained by Company in full compliance with applicable State and Local laws and the provisions of the Uniform Anatomical Gift Act in the United States, and no undue inducements, monetary or otherwise, will be offered to any person to influence their donation of human material.

Company shall provide Achaogen with written documentation that all human materials obtained as a result of research involving human subjects conducted under this contract, by collaborating sites, or by subcontractors identified under this Agreement were obtained with prior approval by the Office for Human Research Protections of an Assurance to comply with the requirements of 45 CFR 46 to protect human research subjects.

Provision by Company to Achaogen of a properly completed Protection of Human Subjects Assurance Identification/IRB Certification/Declaration of Exemption, Form OMB No. 0990-0263 (formerly optional form 310), certifying IRB review and approval of the protocol from which the human materials were obtained constitutes the written documentation required.

H.3: Research Involving Human Fetal Tissue

All research involving human fetal tissue shall be conducted in accordance with the Public Health Service Act, 42 U.S.C. 289g-1 and 289g-2. Implementing regulations and guidance for conducting research on human fetal tissue may be found at 45 C.F.R. 46, Subpart B, and http://grants1.nih.gov/grants/guide/notice-files/not93- 235.html and any subsequent revisions to this NIH Guide to Grants and Contracts (Guide) Notice.

Company shall make available, for audit by Achaogen, the secretary, HHS, the physician statements and informed consents required by 42 U.S.C. 289g-1(b) and (c), or ensure HHS access to those records, if maintained by an entity other than the Contractor.

H.4: Needle Exchange Company shall not use contract funds to carry out any program of distributing sterile needles or syringes for the hypodermic injection of any illegal drug.

H.5: Press Releases Company shall clearly state, when issuing statements, press releases, requests for proposals, bid solicitations and other documents describing projects or programs funded in whole or in part with Federal money: (1) the percentage of the total costs of the program or project which will be financed with Federal money; (2) the dollar amount of Federal funds for the project or program; and (3) the percentage and dollar amount of the total costs of the project or program that will be financed by nongovernmental sources.

H.7: Animal Welfare All research involving live, vertebrate animals shall be conducted in accordance with the Public Health Service Policy on Humane Care and Use of Laboratory Animals. This policy may be accessed at: http://grants1.nih.gov/grants/olaw/references/phspol.htm.

H.8: Protection of Personnel who Work with Nonhuman Primates

All Company personnel who work with nonhuman primates or enter rooms or areas containing nonhuman primates shall comply with the procedures set forth in NIH Policy Manual 3044-2, entitled, Protection of NIH Personnel Who Work with Nonhuman Primates, located at the following URL: http://www1.od.nih.gov/oma/manualchapters/intramural/3044-2/

Page 54 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Prime Contract Provision Clause

H.9: Publications and Publicity

No information related to data obtained under this contract shall be released or publicized without the prior written consent of Achaogen and the Contracting Officer Technical Representative.

In addition to the requirements of HHSAR 352.227-70, Publications and Publicity incorporated by reference in section I of this contract shall acknowledge the support of the Biomedical Advanced Research and Development Authority whenever publicizing the work under this contract in any media by including an acknowledgment substantially as follows:

This project has been funded in whole or in part with Federal funds from the Biomedical Advanced Research and Development Authority, office of the Assistant Secretary for Preparedness and response, Office of the Secretary, Department of Health and Human Services, Under Contract No. HHSO100201000046C. H.10: Reporting Matters Involving Fraud, Waste and Abuse

Anyone who becomes aware of the existence or apparent existence of fraud, waste and abuse in BARDA funded programs is encouraged to report such matters to the HHS Inspector General's Office in writing or on the Inspector General's Hotline. The toll free number is 1-800-HHS-TIPS (1-800-447-8477). All telephone calls will be handled confidentially. The e-mail address is Htips@os.dhhs.gov and the mailing address is: Office of Inspector General Department of Health and Human Services TIPS HOTLINE P.O. Box 23489 Washington, D.C. 20026. H.11 Prohibition on Contractor Involvement with Terrorist Activities

Company acknowledges that U.S. Executive Orders and Laws, including but not limited to E.O. 13224 and P.L. 107-56, prohibit transactions with, and the provision of resources and support to, individuals and organizations associated with terrorism. It is the legal responsibility of Company to ensure compliance with these Executive Orders and Laws. This clause must be included in all subcontracts issued under this contract.

H.15: Privacy Act Applicability

Notification is hereby given that Company and its employees are subject to criminal penalties for violation of the Privacy Act to the same extent as employees of the Government.

H.16: Laboratory license requirement

Company shall comply with all applicable requirements of Section 353 of the Public Health Service Act (Clinical Laboratory Improvement Act as Amended). This requirement shall also be included in any subcontract for services under this contract.

The parties anticipate that no part of the performance of this Agreement will be subject to the Clinical Laboratory Improvement Act As Amended.

H.17: Dissemination of Information

Except for any application to the FDA for approval of a diagnostic, any publication in connection with such FDA filing or approval, and any filing in connection with obtaining patent protection, no information related to data obtained under this contract shall be released or publicized without the prior written consent of the Contracting officer, to be obtained through Achaogen.

H.18: Identification and Disposition of Data

Company will be required to provide certain data generated under this contract to the Department of Health and Human Services (DHHS). DHHS reserves the right to review any other data determined by DHHS to be directly related to and/or generated under this contract. Company shall keep copies of all data required by the Food and Drug Administration (FDA) relevant to this contract for the time period specified by the FDA.

Page 55 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Prime Contract Provision

Clause

H.19: Information on Compliance With Animal Care Requirements

Registration with the U.S. Dept. of Agriculture (USDA) is required to use regulated species of animals for biomedical purposes. USDA is responsible for the enforcement of the Animal Welfare Act (7 U.S.C. 2131 et. seq), http://www.nal.usda.gov/awic/legislat/awa.htm

The Public Health Service (PHS) Policy is administered by the Office of Laboratory Animal Welfare (OLAW) http://grants2.nih.gov/grants/olaw/olaw.htm. An essential requirement of the PHS Policy, http://grants2.nih.gov/grants/olaw/references/phspol.htm is that every institution using live vertebrate animals must obtain an approved assurance from OLAW before they can receive funding from any component of the U.S. Public Health Service.

The PHS Policy requires that Assured institutions base their programs of animal care and use on the Guide for the Care and Use of Laboratory Animals http://www.nap.edu/readingroom/books/labrats/ and that they comply with the regulations (9 C.F.R., subchapter A) http://www.nal.usda.gov/awic/legislat/usdaleg1.htm issued by the U.S. Department of Agriculture (USDA) under the Animal Welfare Act. The Guide may differ from USDA regulations in some respects. Compliance with USDA regulations is an absolute requirement of this Policy.

The Association for Assessment and Accreditation of Laboratory Animal Care International (AAALAC) http://www.aaalac.org is a professional organization that inspects and evaluates programs of animal care institutions at their request. Those that meet the high standards are given accredited status. As of the 2002 revision of the PHS policy, the only accrediting body recognized by PHS is the AAALAC. While AAALAC Accreditation is not required to conduct biomedical research, it is highly desirable. AAALAC uses the Guide as their primary evaluation tool. They also use the Guide for the Care and Use of Agricultural Animals in Agricultural Research and Teaching. It is published by the American Science Societies. http://www.fass.org.

Page 56 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Prime Contract Provision

Clause

H.20: Requirements for Adequate Assurance of Protection of Vertebrate Animal Subjects

The PHYS Policy on Humane Care and Use of Laboratory Animals requires that applicant organizations proposing to use vertebrate animals file a written Animal Welfare Assurance with the Office for Laboratory Animal Welfare (OLAW), establishing appropriate policies and procedures to ensure the humane care and use of live vertebrate animals involved in research activities supported by the PHS. The PHS Policy stipulates that an applicant organization, whether domestic or foreign, bears responsibility for the humane care and use of animals in PHS-supported research activities. Also the PHS policy defines animal as any live, vertebrate animal used, or intended for use, in research, research training, experimentation, biological testing or for related purposes. This policy implements and supplements the U.S. Government Principles for the Utilization and Care of Vertebrate Animals Used in Testing, Research, and Training, and requires that institutions use the Guide for the Care and Use of Laboratory Animals as a basis for developing and implementing an institutional animal care use program. This Policy does not affect applicable State or local laws or regulations that impose more stringent standards for the care and use of laboratory animals. All institutions are required to comply, as applicable, with the Animal Welfare Act, as amended and other Federal statutes and regulations relating to animals. These documents are available from the Office of Laboratory Animal Welfare, National Institutes of Health, Bethesda, MD 20892, (301) 496-7163. http://grants.nih.gov/grants/olaw/olaw.htm.

No PHYS supported work or research involving vertebrate animals will be conducted by an organization, unless that organization is operating in accordance with an approved Animal Welfare Assurance and provides verification that the Institutional Animal Care and Use Committee (IACUC) has reviewed and approved the proposed activity in accordance with the PHS policy. Applications may be referred by the PHS back to the institution for further review in the case of an apparent or potential violations of the PHS policy. No award to an individual will be made unless that individual is affiliated with an assured organization that accepts responsibility for compliance with the PHS Policy. Foreign applicant organizations applying for PHS awards for activities involving vertebrate animals are required to comply with PHS Policy or provide evidence that acceptable standards for the humane care and use of animals will be met. Foreign applicant organizations are not required to submit IACUC approval, but should provide information that is satisfactory to the Government to provide assurances for the humane care of such animals.

H.21: Approval of Required Assurance by OLAW

Under governing regulations, federal funds which are administered by DHHS, Office of Biomedical Advanced Research and Development Authority (BARDA) shall not be expended by the contractor for research involving live vertebrate animals, nor shall live vertebrate animals be involved in research activities by Company under this award unless a satisfactory assurance of compliance with 7 U.S.C. 2316 and 9 CFR Sections 2.25-2.28 is submitted within 30 days of the date of this award and approved by the Office of Laboratory Animal Welfare (OLAW). Each performance site (if any) must also assure compliance, with the following restriction: Only activities which do not directly involve live vertebrate animals (i.e., are clearly severable and independent from those activities) may be conducted by the contractor or individual performance sites pending OLAW approval of their respective assurance of compliance.

Page 57 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Prime Contract Provision

Clause

H.22: Registration with the Select Agent Program for Work involving the possession, use, and/or transfer of select biological agents or toxins

Company shall not conduct work involving select agents or toxins under this contract until it and any associated subcontractor(s) comply with the following:

For prime or subcontract awards to domestic institutions that possess, use, and/or transfer Select Agents under this contract, the institution must comply with the provisions of 42 C.F.R. part 73, 7 C.F.R. part 331, and/or 9 C.F.R. part 121 ( http://www.aphis.usda.gov/programs/ag_selectagent/FinalRule3-18-05.pdf ) as required, before using NIH funds for work involving a Select Agent or Toxin. No government funds can be used for research involving a Select Agent or Toxin at a domestic institution without a valid registration certificate.

For prime or subcontract awards to foreign institutions that possess, use, and/or transfer a Select Agent or Toxin, before using NIH funds for any work directly involving a Select Agent or Toxin, the foreign institution must provide information satisfactory to the government that safety, security, and training standards equivalent to those described in 42 C.F.R. part 73, 7 C.F.R. part 331, and/or 9 C.F.R. part 121 are in place and will be administered on behalf of all Select Agent or Toxin work supported by these funds. The process for making this determination includes inspection of the foreign laboratory facility by a government representative. During this inspection, the foreign institution must provide the following information: concise summaries of safety, security, and training plans; names of individuals at the foreign institution who will have access to the Select Agents and procedures for ensuring that only approved and appropriate individuals, in accordance with institution procedures, will have access to the Select Agents under the contract; and copies of or links to any applicable laws, regulations, policies, and procedures applicable to that institution for the safe and secure possession, use, and/or transfer of select agents. No funds can be used for work involving a Select Agent or Toxin at a foreign institution without written approval from Achaogen.

Listings of HHS select agents and toxins, and overlap select agents or toxins as well as information about the registration process for domestic institutions, are available on the Select Agent Program Web site at http:// www.cdc.gov/od/sap/ and http://www.cdc.gov/od/sap/docs/salist.pdf.

Listings of USDA select agents and toxins as well as information about the registration process for domestic institutions are available on the APHIS/USDA website at: http://www.aphis.usda.gov/programs/ag_selectagent/ index.html and: http://www.aphis.usda.gov/programs/ag_selectagent/ag_bioterr_forms.html

For foreign institutions, see the NIAID Select Agent Award information: http://www.niaid.nih.gov/ncn/clinical/default_biodefense.htm.

H.23: EPA Energy Star Requirements

All microcomputers, including personal computers, monitors, and printers purchased with government funds in the performance of a contract shall be equipped with or meet the energy efficient low-power standby feature as defined by the EPA Energy Star program unless the equipment always satisfies Energy Star efficiency levels.

Page 58 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Prime Contract Provision Clause

H.24: Acknowledgement of Federal Funding

(a)Section 507 of P.L. 104-208 mandates that contractors funded with Federal dollars, in whole or in part, acknowledge Federal funding when issuing statements, press releases, requests for proposals, bid solicitations and other documents. Contractors are required to state (1) the percentage and dollar amounts of the total program or project costs financed with federal money, and (2) the percentage and dollar amount of the total costs financed by nongovernmental sources. This requirement is in addition to the continuing requirement to provide an acknowledgement of support and disclaimer on any publication reporting the results of a contract funded activity. (b)Publication and Publicity. The contractor shall acknowledge the support of the Department of Health and Human Service, Office of the Assistant Secretary for Preparedness and Response, Biomedical Advanced Research and Development Authority whenever publicizing the work under this contract in any media by including an acknowledgment substantially as follows: This project has been funded in whole or in part with Federal funds from the Office of the Assistant Secretary for Preparedness and Response, Biomedical Advanced Research and Development Authority, under Contract no. HHSO100201000046C. (c)Press Releases. Pursuant to Section 508 of Public Law 105-78, the contractor shall clearly state, when issuing statements, press releases, requests for proposals, bid solicitations and other documents describing projects or programs funded in whole or in part with federal money that: (1) the percentage of the total costs of the program or project which will be financed with federal money; (2) the dollar amount of Federal funds for the project or program; and (3) the percentage and dollar amount of the total costs of the project or program that will be financed by nongovernmental sources. H.25: Manufacturing Standards

The Current Good Manufacturing Practice Regulations (cGMP) (21 C.F.R. Parts 210-211) and regulations pertaining to biological products (21 C.F.R. Part 600) will be the standard to be applied for manufacturing, processing, packing, storage, and delivery of this product.

If at any time during the life of the contract, Company fails to comply with cGMP in the manufacturing, processing and packaging of this product and such failure results in a material adverse effect on the safety, purity or potency of this product (a material failure), the Contractor shall have thirty (30) calendar days from the time such material failure is identified to cure such material failure. If the Contractor fails to take such an action within the thirty (30) calendar day period, then the contract may be terminated for default.

H.26: Export Control Notification

Company is responsible for ensuring compliance with all export control laws and regulations that may be applicable to the export of and foreign access to their proposed technologies.

Page 59 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.





Prime Contract Provision Clause

H.27: Institutional responsibility Regarding Conflicting Interests of Investigators

Company shall comply with the requirements of 45 CFR Part 94, Responsible Prospective Contractors, which promotes objectivity in research by establishing standards to ensure that investigators (defined as the principle investigator and any other person who is responsible for design, conduct, or reporting of research funded under BARDA contracts) will not be biased by any conflicting financial interest. For the purposes of this part relating to financial interest, investigator includes the investigator's spouse and dependent children.

Company shall at a minimum:

(a)Maintain a written, enforceable policy on conflict of interest and inform each investigator of the policy, the investigator's reporting responsibilities, and the applicable regulations. The contractor must take reasonable steps to ensure that investigators working as collaborators or subcontractors comply with the regulations. (b)Designate and official to review financial disclosure statements from each investigator participating in BARDA-funded research. Based on established guidelines consistent with the regulations, the designated official must determine whether a conflict of interest exists, and if so, determine what actions should be taken to manage, reduce, or eliminate such a conflict. (c)Require updating of financial disclosure statements during the period of award. (d)Maintain records taken under this provision for three years after final payment. (e)Establish adequate enforcement mechanisms. If a conflict of interest is identified, the Institution shall report to Achaogen the existence of the conflicting interest found. This report shall be made and the conflicting interest managed, reduced, or eliminated, at least on a temporary basis, within thirty (30) days of that identification.



ORDER OF PRECEDENCE

In the event of a conflict between the terms of this Appendix and any term of the Agreement or an Exhibit or other appendix issued there under, the terms of this Appendix shall govern.



Page 60 of 60 [***] Certain information in this document has been omitted and filed separately with the Securities and Exchange Commission. Confidential Treatment has been requested with respect to the omitted portions.
Highlight the parts (if any) of this contract related to Insurance that should be reviewed by a lawyer. Details: Is there a requirement for insurance that must be maintained by one party for the benefit of the counterparty?

Exhibit 10.1

COOPERATION AGREEMENT

This Cooperation Agreement (Agreement) is entered into as of July 1, 2020, by and between e.l.f. Beauty, Inc., a Delaware corporation (the Company), and Marathon Partners Equity Management, LLC (Marathon Partners), Marathon Partners L.P., Marathon Focus Fund L.P., Marathon Partners LUX Fund, L.P., Cibelli Research & Management, LLC and Mario Cibelli (collectively, the Marathon Parties) (each of the Company, on the one hand, and the Marathon Parties, on the other hand, a Party to this Agreement, and collectively, the Parties).

RECITALS

WHEREAS, the Marathon Parties have voting power or sole dispositive power or otherwise have beneficial ownership of 2,585,000 shares of the common stock, par value $0.01 per share, of the Company (the Common Stock) as of the date of this Agreement;

WHEREAS, Marathon Partners submitted a letter to the Company on May 28, 2020 (the Nomination Notice) nominating a slate of director candidates to be elected to the Board of Directors of the Company (the Board) at the Company's 2020 Annual Meeting of Shareholders (the 2020 Annual Meeting); and

WHEREAS, as of the date of this Agreement, the Company and the Marathon Parties have determined to come to an agreement with respect to certain matters set forth below.

NOW, THEREFORE, in consideration of the foregoing premises and the mutual covenants and agreements contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are acknowledged, the Parties to this Agreement, intending to be legally bound, agree as follows:

1. Board Nomination; Certain Information; Other Board and Company Actions.

(a) Lori Keith (the New Director) has provided the Company with (i) fully completed and executed copies of the Company's standard director & officer questionnaire, representation and agreement letter, and other reasonable and customary director onboarding documentation, including (A) all information reasonably requested by the Company that is required to be disclosed for directors, candidates for directors, and their affiliates and representatives in a proxy statement or other filings under applicable law or regulation or stock exchange rules or listing standards, in each case, relating to their appointment, nomination or election as a director of the Company and (B) information reasonably requested by the Company in connection with assessing eligibility, independence and other criteria applicable to directors or satisfying compliance and legal or regulatory obligations, in each case, relating to their appointment, nomination or election as a director of the Company and required by the Company in connection with the appointment or election of new members of the Board, (ii) an executed consent of the New Director to be named in any proxy statement or other filings under applicable law or stock exchange rules or listing standards and to serve as a Class III Director and (iii) a written representation that the New Director, if elected as a director of the Company, would be in compliance, and will comply with, all applicable confidentiality, corporate governance, conflict of interest, Regulation FD, code of conduct and ethics, stock ownership and trading policies and guidelines, and other policies of the Company applicable to members of the Board (collectively, the Information), and has cooperated with a background check.

(b) Based on the Information, the Nominating and Corporate Governance Committee (the Nominating Committee) of the Board and the Board have determined that the New Director may serve as an independent director of the Company in accordance with the rules and listing standards of the New York Stock Exchange (NYSE) and applicable rules and regulations of the U.S. Securities and Exchange Commission (the SEC).

(c) As promptly as practicable, but in no event later than two business days following the execution of this Agreement, the Nominating Committee and the Board shall take all necessary action to (i) increase the size of the Board from eight to nine directors, with such new Board seat to be in Class III, (ii) appoint the New Director as a Class III director on the Board and (iii) appoint the New Director to the Nominating Committee.





(d) Immediately following the execution of this Agreement by the Parties, the Marathon Parties shall send a letter to the Secretary of the Company irrevocably withdrawing (i) the Nomination Notice, and, accordingly, (ii) their nomination of Mario Cibelli, Dhiren Fonseca and Beth Birnbaum (the Nominations) for election to the Board as Class I directors at the 2020 Annual Meeting and (iii) the Marathon Parties' demand letter pursuant to Section 220 of the Delaware General Corporation Law, dated April 12, 2019.

(e) The Board shall take all necessary action to include in the proposals to be voted on at the 2020 Annual Meeting (i) a say-on-pay proposal of the Company and (ii) a vote as to the frequency at which say-on-pay proposals will be presented to and voted on by the stockholders at future annual meetings of the Company, which shall include a recommendation by the Board that stockholders vote FOR annual say-on-pay proposals.

(f) The Board shall take all necessary action to amend Section 3.1(a) of the 2016 Equity Incentive Award Plan of the Company (the 2016 Incentive Plan) to reduce the maximum automatic annual percentage increase of shares of Common Stock reserved for issuance under the 2016 Incentive Plan from 4% to 2%. During the Support Period (as defined below), the Board shall not (i) adopt a new equity incentive award plan or otherwise seek to amend the 2016 Incentive Plan to increase the Share Limit (as defined in the 2016 Incentive Plan) or (ii) issue Awards (as defined in the 2016 Incentive Plan) in excess of the Share Limit (as defined in the 2016 Incentive Plan).

(g) The New Director (or any Replacement (as defined below)), in addition to all current directors, will (A) comply with all policies, procedures, codes, rules, standards and guidelines applicable to members of the Board and (B) keep confidential all Company confidential information and not disclose to any third parties (including the Marathon Parties) discussions or matters considered in meetings of the Board or Board committees.

(h) Annual grants of equity awards to executive officers of the Company in 2021 will take place during the open trading window following the Company's fourth quarter earnings call in 2021. The proxy statement for the 2020 Annual Meeting shall include language describing the obligation of the Company set forth in this Section 1(h).

(i) Nothing in this Agreement shall be deemed to abridge or limit the fiduciary duties of any member of the Board under Delaware law.

(j) The New Director (or any Replacement (as defined below)) may attend as a non-voting observer any meeting(s) of the Compensation Committee of the Board (the Compensation Committee) held following the date of this Agreement and during the Support Period, and shall receive a copy of any materials disseminated to Compensation Committee members in connection with such meeting(s).

2. Representations of the Marathon Parties. The Marathon Parties represent and warrant to the Company as of the date hereof as follows:

(a) The Marathon Parties are the beneficial owners of 2,585,000 shares of Common Stock, such shares of Common Stock constitute all of the Common Stock beneficially owned by the Marathon Parties, and (i) the Marathon Parties' interests in the Common Stock and debt or other securities of the Company is as set forth on Exhibit A, (ii) except as set forth on Exhibit A, the Marathon Parties do not currently have, and do not currently have any right to acquire, any interest in any other securities of the Company (or any rights, options or other securities convertible into or exercisable or exchangeable (whether or not convertible, exercisable or exchangeable immediately or only after the passage of time or the occurrence of a specified event) for such securities or any obligations measured by the price or value of any securities of the Company or any of its controlled Affiliates, including any swaps, puts, calls, appreciation rights or other derivative arrangements designed to produce economic benefits and risks that correspond to the ownership of Common Stock, whether or not any of the foregoing would give rise to beneficial ownership, and whether or not to be settled by delivery of Common Stock, payment of cash or by other consideration, and without regard to any short position under any such contract or arrangement) (collectively, Securities of the Company) and (iii) the Marathon Parties will not, directly or indirectly, compensate or agree to compensate the New Director for her service as a director of the Company with any cash, securities (including any rights or options convertible into or exercisable for or exchangeable into securities or any profit sharing agreement or arrangement), or other form of compensation. The terms

2





beneficially owns and beneficial ownership for all purposes under this Agreement shall have the meanings set forth in Rule 13d-3 promulgated by the SEC under the Securities Exchange Act of 1934, as amended (the Exchange Act). As used in this Agreement, the terms Affiliate and Associate shall have the respective meanings set forth in Rule 12b-2 promulgated by the SEC under the Exchange Act.

(b) The Marathon Parties have no agreements, understandings or undertakings with any third party to share or delegate disposition or voting control over any of the securities set forth on Exhibit A, or to transfer, hypothecate or lend any of the securities set forth on Exhibit A.

(c) Each of the Marathon Parties represents and warrants to the Company as of the date hereof that it has the power and authority to execute and deliver this Agreement. This Agreement (i) has been duly and validly authorized by each of the Marathon Parties, and constitutes a legal, valid and binding obligation of each of the Marathon Parties, enforceable against each of the Marathon Parties in accordance with its terms except as may be limited by bankruptcy, insolvency or similar laws affecting creditors' rights and general equitable principles, (ii) does not require the approval of any investor in or member of the Marathon Parties and (iii) does not violate any law, order of any court or any governmental agency or regulation or the charter or any organizational document of the Marathon Parties, or conflict with, result in a breach of or constitute a default under any agreement or instrument by which the Marathon Parties or any of their respective assets is bound.

3. Representations of the Company. The Company represents and warrants to the Marathon Parties as of the date hereof that it has the corporate power and authority to execute and deliver this Agreement. This Agreement (i) has been duly and validly authorized by the Company and constitutes a legal, valid and binding obligation of the Company, enforceable against the Company in accordance with its terms except as may be limited by bankruptcy, insolvency or similar laws affecting creditors' rights and general equitable principles and (ii) does not violate any law, order of any court or any agency or regulation or the Company's Certificate of Incorporation or the Amended and Restated Bylaws of the Company (the Bylaws), or conflict with, result in a breach of or constitute a default under any agreement or instrument by which the Company or any of its assets or the assets of its subsidiaries are bound. The Company further represents and warrants to the Marathon Parties as of the date hereof that since March 2, 2019 it has not granted any performance equity awards to any named executive officers other than those disclosed or referenced by the Company in its Forms 4 filed with the SEC in June 2020.

4. Support Period Covenants.

(a) During the period commencing on the date hereof and ending at 11:59 pm New York Time on the date that is thirty (30) days prior to expiration of the advance notice period for the submission by stockholders of director nominations for consideration at the Company's 2021 Annual Meeting of Stockholders (the 2021 Annual Meeting) as determined by applicable law and set forth in the Bylaws (such period, as modified, if applicable, in Section 4(b) below, the Support Period), the Marathon Parties shall appear in person or by proxy for quorum purposes at the 2020 Annual Meeting and any other meeting of stockholders of the Company, including any adjournment or postponement thereof, to vote all of the shares of Common Stock beneficially owned by the Marathon Parties on the record date for such meeting (i) in favor of all persons nominated by the Board to serve as directors of the Company and against any stockholder nominated candidate not endorsed by the Board, (ii) to ratify the appointment of the Company's independent registered public accounting firm, (iii) in accordance with the Board's recommendation with respect to the Company's say-on-pay proposal and compensation plans and any amendments thereto and (iv) in favor of any other proposals recommended by the Board, provided, that with respect to any extraordinary matter, including any merger, acquisition, recapitalization, restructuring, financing, disposition, distribution, spin-off, asset sale, joint venture or other business combination involving the Company or its subsidiaries which requires a vote of the Company's stockholders, the Marathon Parties shall have the right to vote the shares of Common Stock beneficially owned by the Marathon Parties in their sole discretion. The Marathon Parties shall provide written evidence of such vote to the Company no later than ten (10) business days prior to the 2020 Annual Meeting.

(b) Notwithstanding the foregoing, if either:

3





(i) at any time between the date of this Agreement and the date that is thirty (30) days prior to the expiration of the advance notice period for the submission by stockholders of director nominations for consideration at the 2021 Annual Meeting as determined by applicable law and set forth in the Bylaws (such date, the 2021 Annual Meeting Nomination Window Date), the Marathon Parties do not meet the Minimum Ownership Threshold (as defined below), or

(ii) as of the 2021 Annual Meeting Nomination Window Date, all of the following conditions have been met:

a. if the New Director or her Replacement is a director on the Board as of the 2021 Annual Meeting Nomination Window Date, the New Director or her Replacement (as applicable) is a member of the Nominating Committee as of such date,

b. between the date of this Agreement and the 2021 Annual Meeting Nomination Window Date, Tarang Amin has not entered into a voting agreement or similar agreement that would subject any Securities of the Company beneficially owned by Mr. Amin to any arrangement or agreement with respect to the voting thereof with any other person that is a holder of any Securities of the Company and that is not affiliated with Mr. Amin or his estate planning, or that would give Mr. Amin the power to vote or direct the voting of any Securities of the Company beneficially owned by any other person that is not affiliated with Mr. Amin or his estate planning,

c. between the date of this Agreement and the 2021 Annual Meeting Nomination Window Date, the Company has not issued shares of Common Stock (and/or Securities of the Company convertible into, or exercisable for, shares of Common Stock) in any transaction that represents more than 20% of the issued and outstanding shares of Common Stock (including any Securities of the Company convertible into, or exercisable for, shares of Common Stock) immediately prior to such issuance,

d. the Company has confirmed that the proxy statement for the 2021 Annual Meeting shall include language describing the obligation of the Company set forth in Section 1(h) above as relates to annual grants of equity awards to executive officers of the Company in 2022, and

e. the Company has confirmed that any director(s) or officer(s) of the Company who beneficially owned 3% or more of the issued and outstanding shares of Common Stock as of the record date for the 2020 Annual Meeting voted all such shares at the 2020 Annual Meeting in favor of annual say-on-pay proposal frequency at future annual meetings of the Company,

then, for all purposes under this Agreement, the Support Period shall not expire on the 2021 Annual Meeting Nomination Window Date, and instead the Support Period shall automatically be extended until 11:59 pm New York Time on the date that is thirty (30) days prior to expiration of the advance notice period for the submission by stockholders of director nominations for consideration at the Company's 2022 Annual Meeting of Stockholders as determined by applicable law and set forth in the Bylaws for all purposes under this Agreement, and the Marathon Parties shall be required to (x) appear in person or by proxy at the 2021 Annual Meeting or any other meeting of stockholders of the Company held on or after the 2021 Annual Meeting Nomination Window Date and prior to the end of the Support Period, (y) vote any of the shares of Common Stock beneficially owned by the Marathon Parties in accordance with Section 4(a)(i), (ii), (iii) and (iv) at any meeting of stockholders of the Company held on or after the 2021 Annual Meeting Nomination Window Date and prior to the end of the Support Period, provided, however, that in the event that Institutional Shareholder Services Inc. (ISS) recommends otherwise with respect to the Company's say-on-pay proposal or any proposal relating to any compensation plan submitted for shareholder approval at the 2021 Annual Meeting, including any amendments thereto, each of the Marathon Parties will be permitted to vote in accordance with the ISS

4





recommendation in its discretion, and (z) provide written evidence of such vote by the Marathon Parties at any meeting of stockholders of the Company held on or after the 2021 Annual Meeting Nomination Window Date and prior to the end of the Support Period (including the 2021 Annual Meeting) no later than ten (10) business days prior to any such meeting (including the 2021 Annual Meeting). As used herein, the Minimum Ownership Threshold shall mean beneficial ownership equal to or greater than 2.0% of the issued and outstanding shares of Common Stock. The Marathon Parties shall provide notice to the Company within two business days following the date on which the Marathon Parties no longer meet the Minimum Ownership Threshold.

(c) If at any time during the Support Period (x) the New Director is unable to serve out her term as a Class III Director on the Board for any reason, and (y) as of such time, the Marathon Parties have maintained since the date of this Agreement the Minimum Ownership Threshold and the Marathon Parties have provided evidence of such ownership, together with a certification of such ownership, to the Company, then the Marathon Parties and the Company shall negotiate in good faith to propose a mutually-agreed upon replacement director (the Replacement) to be appointed to the Board to serve as her successor for the remainder of her current term as a Class III Director in accordance with the Bylaws, provided such Replacement (i) qualifies as independent pursuant to the rules and listing standards of the NYSE and applicable SEC rules and regulations, (ii) has provided the Company with the Information, (iii) has cooperated with a background check and (iv) has executed all documents required to be executed by directors of the Company. The Replacement shall be promptly appointed to the Board and at least one standing committee of the Board, subject to the approval by each of the Nominating Committee and the Board, after conducting a good faith customary due diligence process and consistent with the Board's fiduciary duties.

5. Standstill Covenants.

(a) Except as otherwise contemplated in Section 4 of this Agreement, at all times during the Support Period, the Marathon Parties shall not, and shall cause their Affiliates and Associates and their and such Affiliates' and Associates' respective equity owners (including members and limited partners), directors, officers, managers and employees not to, and will direct their consultants, agents, representatives, attorneys and advisors (to the extent directly or indirectly acting on behalf of the Marathon Parties) (collectively, the Marathon Party Representatives) not to, directly or indirectly, in any manner, alone or in concert with others:

(i) make, engage, solicit, or in any way participate in any solicitation of proxies (as such term under the Exchange Act) or consents to vote, or knowingly advise, encourage or influence any person or entity with respect to the voting of any Securities of the Company or become a participant in any contested solicitation for the election of directors with respect to the Company (as such terms are defined or used under the Exchange Act) (other than a solicitation or acting as a participant in support of all of the nominees recommended by the Board at any stockholder meeting);

(ii) propose or otherwise solicit stockholders of the Company for the approval of one or more stockholder proposals (whether made pursuant to Rule 14a-8 under the Exchange Act or otherwise) or call, attempt to call or solicit consents to call a special meeting of stockholders of the Company;

(iii) agree or propose to grant any proxies with respect to, or deposit any Securities of the Company in a voting trust or similar arrangement or subject any Securities of the Company to any arrangement or agreement with respect to the voting thereof, except as expressly set forth in Section 4 of this Agreement;

(iv) take any action to form, join, encourage, influence or in any way participate in any partnership, limited partnership, syndicate or other group (as such term is contemplated in Rule 13d-5 promulgated under the Exchange Act) with respect to the Securities of the Company (other than a group formed with an Affiliate of the Marathon Parties) or otherwise act in concert with any person or entity for the purpose of circumventing the provisions or purposes of this Agreement;

(v) purchase or otherwise acquire, or offer, seek, propose or agree to acquire, ownership (including beneficial ownership) of the Securities of the Company, any direct or indirect rights or options to

5





acquire any such Securities of the Company, any derivative securities or contracts or instruments in any way related to the price of shares or value of Common Stock, any other securities of the Company, or any assets or liabilities of the Company, provided that the Marathon Parties and their Affiliates, in the aggregate, may acquire beneficial ownership of up to 12.5% of the Company's outstanding shares of Common Stock;

(vi) other than in open-market transactions where the identity of the purchaser is not known and in underwritten widely dispersed public offerings, sell, offer or agree to sell, directly or indirectly, through swap or hedging transactions or otherwise, the Securities of the Company or any rights decoupled from the underlying Securities of the Company held by the Marathon Parties or any of their Affiliates or Associates to any person or entity not (A) a party to this Agreement, (B) a member of the Board or (C) an officer of the Company (any person or entity not set forth in clauses (A)-(C) shall be referred to as a Third Party), that would knowingly result in such Third Party, together with its Affiliates and Associates, owning, controlling or otherwise having any beneficial or other ownership interest in the aggregate of more than 4.9% of the shares of Common Stock outstanding at such time, other than Schedule 13G filers that are mutual funds, pension funds, index funds or investment fund managers with no known history of activism or known plans to engage in activism, except in a transaction approved in advance by the Board;

(vii) effect or seek to effect, offer or propose to effect, cause or participate in, or knowingly assist or facilitate any other person or entity to effect or seek, offer or propose to effect or participate in, any tender or exchange offer, merger, consolidation, division, acquisition, scheme, arrangement, business combination, recapitalization, reorganization, sale or acquisition of material assets, liquidation, dissolution or other extraordinary transaction involving the Company or any of its subsidiaries or joint ventures or any of their respective securities (each, an Extraordinary Transaction), or make any public statement with respect to an Extraordinary Transaction; provided, however, that nothing in this Agreement shall prevent the Marathon Parties from making a public statement about how they intend to vote and the reasons therefor with respect to any Extraordinary Transaction to which any executive officer or director of the Company is a party (other than customary support agreements) and that requires a vote of the Company's stockholders; provided further, that this clause shall not preclude the tender by the Marathon Parties or any of their Affiliates or Associates of any Securities of the Company into any tender or exchange offer which has been approved and recommended to stockholders of the Company by the Board;

(viii) (A) seek or solicit support for (whether publicly or privately) any written consent of stockholders of the Company, (B) seek representation on, or nominate any candidate to, the Board, except as set forth in Section 1 of this Agreement, (C) seek the removal of any member of the Board, (D) conduct a referendum of stockholders, (E) institute any litigation against the Company, its directors or its officers other than to (1) enforce the provisions of this Agreement and (2) make counterclaims with respect to any proceeding initiated by, or on behalf of, the Company against the Marathon Parties, or (F) make a request for any stockholder list or other Company books and records, whether pursuant to Section 220 of the Delaware General Corporation Law or otherwise;

(ix) knowingly encourage, advise or influence any other person or assist any Third Party in so encouraging, assisting or influencing any person or entity with respect to the giving or withholding of any proxy vote at the 2020 Annual Meeting or the 2021 Annual Meeting (including any vote no or withhold vote or similar campaign);

(x) take any action in support of or make any proposal or request that constitutes: (A) advising, controlling, changing or influencing the Board or management of the Company, including any plans or proposals to change the number or term of directors or to fill any vacancies on the Board or unfilled newly-created directorships; (B) any material change in the capitalization, stock repurchase programs and practices or dividend policy of the Company; (C) any other material change in the Company's management, business or corporate structure, including, without limitation, its capital allocation, expense structure, business operations or strategies or its management or other personnel; (D) seeking to have the Company waive or make amendments or modifications to the Company's Certificate of Incorporation or the Bylaws, or other actions that may impede or facilitate the acquisition of control of the Company by any person or entity;

6





(E) causing a class of Securities of the Company to be delisted from, or to cease to be authorized to be quoted on, any securities exchange; or (F) causing a class of Securities of the Company to become eligible for termination of registration pursuant to Section 12(g)(4) of the Exchange Act;

(xi) otherwise act in concert with any person or entity to seek to control or direct the management, Board (or any individual members thereof), stockholders or policies of the Company;

(xii) take any action that would require the Marathon Parties or any of their Affiliates or Associates to file a statement of beneficial ownership report on Schedule 13D or any amendment thereto with the SEC, other than solely as a result of the purchase or sale by the Marathon Parties of Securities of the Company set forth on Exhibit A;

(xiii) make any public disclosure, announcement or statement regarding any intent, purpose, plan or proposal with respect to the Board, the Company, its management, policies or affairs, any Securities of the Company or assets of the Company or this Agreement;

(xiv) enter into substantive discussions, negotiations, agreements or understandings with any Third Party with respect to the foregoing, or solicit, assist, prompt, induce or attempt to induce any Third Party to take any action or make any statement with respect to any of the foregoing, or otherwise take or cause any action or make any statement inconsistent with any of the foregoing; or

(xv) request, directly or indirectly, any amendment or waiver of this Section 5(a).

(b) Notwithstanding anything contained in this Agreement to the contrary:

(i) Nothing in this Section 5(a) shall prohibit or restrict the Marathon Parties from taking any action necessary to comply with any law, rule or regulation or any action required by any governmental or regulatory authority or stock exchange that has jurisdiction over the Marathon Parties or any of their Affiliates or Associates. The provisions of this Section 5(a) shall also not prevent the Marathon Parties from freely voting their Shares (except as otherwise provided in this Agreement) or taking any actions except as specifically contemplated in this Agreement.

(ii) The Marathon Parties shall be responsible for any breach of this Section 5(a) by any of their Affiliates or Associates or any Marathon Party Representatives.

6. Mutual Non-Disparagement; No Public Statements.

(a) Subject to applicable law, the Company, on the one hand, and each of the Marathon Parties on the other hand, covenants and agrees that, during the Support Period or if earlier, until such time as the other Party or any of its or her officers, directors, employees, subsidiaries, Affiliates, Associates, agents, attorneys or other representatives (collectively, the Representatives) shall have breached this section, neither it nor any of its respective Representatives acting, directly or indirectly, at its direction or on its behalf, shall in any way publicly (including by any communication with other investors or prospective investors in the Company where such communications could reasonably be expected to be made public or trigger a public disclosure obligation, with securities analysts or any member of traditional or digital media) criticize, disparage, call into disrepute or otherwise defame or slander the other Party or such other Party's Representatives (including any current officer or director of a Party or a Party's subsidiaries who no longer serves in such capacity at any time following the execution of this Agreement), or any of their businesses, products or services, in any manner that would reasonably be expected to damage the business or reputation of such other Party.

(b) During the Support Period and except for the filing or amendment of a statement of beneficial ownership report on Schedule 13D in relation to the purchase or sale of Common Stock, neither the Marathon Parties nor any of their Representatives, acting at the direction of, or on behalf of, the Marathon Parties shall make any public statement relating to the Company nor take any action which would reasonably be expected to require any public filing

7





related to the Company without prior written approval from the Company; provided, however, that nothing in this Agreement shall prevent the Marathon Parties from making a public statement about how they intend to vote and the reasons therefor with respect to any Extraordinary Transaction to which any executive officer or director of the Company is a party (other than customary support agreements) and that requires a vote of the Company's stockholders.

(c) Each Party shall be responsible for any breach of this Section 6 by any of their respective Representatives.

(d) During the Support Period, so long as the Marathon Parties have maintained since the date of this Agreement the Minimum Ownership Threshold, (i) management of the Company (together with the Company's Lead Independent Director, should such director elect to participate) will hold a customary investor conference call, for up to 45 minutes, with Mr. Cibelli and other representatives of the Marathon Parties following each of the Company's quarterly and annual earnings calls, and (ii) promptly following such call, the Lead Independent Director of the Company (together with any other independent directors of the Company selected by the Lead Independent Director to attend such meeting) will participate in a call with Mr. Cibelli and other representatives of the Marathon Parties without management of the Company present for up to 15 minutes (the calls in (i) and (ii), Quarterly Investor Conference Calls). The Marathon Parties shall provide the Company with a detailed agenda of discussion topics for the portion of the Quarterly Investor Conference Call with the Lead Independent Director no later than three business days prior to the date of such Quarterly Investor Conference Call. Should the Marathon Parties forgo a Quarterly Investor Conference Call, any unused minutes from such relinquished Quarterly Investor Conference Call shall carry over to the Quarterly Investor Conference Call being held the following quarter; provided, however, for the avoidance of doubt, any unused minutes from a Quarterly Investor Conference Call shall not carry over more than one successive quarter.

(e) Between the date of this Agreement and the 2021 Annual Meeting Nomination Window Date, no Marathon Party or any of their Representatives will contact or communicate with the Company or any of its Representatives (including any member of the Board) in any way or through any media other than at a Quarterly Investor Conference Call, in connection with arranging any such Quarterly Investor Conference Call or in connection with the Marathon Party's specific rights and obligations under this Agreement. Any communications from any Marathon Party or any of their Representatives in connection with arranging any such Quarterly Investor Conference Call or in connection with the Marathon Party's rights and obligations under this Agreement must be directed to the Parties in accordance with the notice provisions in Section 8(l), and no Marathon Party or any of their Representatives will contact or communicate with the Company or any of its Representatives (including any member of the Board) in any other manner unless agreed to in writing by the Company.

(f) In the event that the Support Period is automatically extended pursuant to Section 4(b), then, following the 2021 Annual Meeting Nomination Window Date, the Marathon Parties agree that any and all contacts and communications regarding the Company, as well as any request by any of the Marathon Parties or any of the Marathon Party Representatives to contact, communicate or meet with the Company or any of its Representatives (including any member of the Board), shall be directed solely to the Company's General Counsel. Any such communications from any of the Marathon Parties or any of the Marathon Party Representatives in connection with arranging any Quarterly Investor Conference Call or in connection with the Marathon Parties' rights and obligations under this Agreement shall be directed solely to the Company's General Counsel.

7. Press Release. The Parties agree that the Company shall issue a press release (the Press Release) in substantially the form attached hereto as Exhibit B promptly following the execution and delivery of this Agreement by the Parties.

8. Miscellaneous.

(a) Specific Enforcement; Special Remedy. Each of the Parties agrees that the other Party would be irreparably injured in the event that any provision of the Agreement is breached or not performed. Accordingly, it is agreed that each Party shall be entitled to temporary and permanent injunctive relief with respect to each and any breach or purported repudiation of this Agreement by the other and to specifically enforce strict adherence to this Agreement and the terms and provisions hereof against the other in any action instituted in a court of competent

8





jurisdiction, in addition to any other remedy which such aggrieved Party may be entitled to obtain. Moreover, in the event of the breach of any of the provisions of this Agreement, timeliness in obtaining relief is of the essence.

(b) Amendments; Waiver. Neither this Agreement nor any term hereof may be changed, waived, discharged or terminated orally or in writing, except that any term of this Agreement may be amended by a writing signed by the Parties, and the observance of any such term may be waived (either generally or in a particular instance and either retroactively or prospectively) solely in a writing signed by the Party against whom such waiver is to be asserted. No delay on the part of either Party in exercising any right, power or privilege hereunder shall operate as a waiver thereof, nor shall any waiver on the part of either Party of any right, power or privilege hereunder operate as a waiver of any other right, power or privilege hereunder, nor shall any single or partial exercise of any right, power or privilege hereunder, preclude any other or further exercise thereof or the exercise of any other right, power or privilege hereunder.

(c) Successors and Assigns. This Agreement shall inure to the benefit of and be binding upon the successors and assigns of each of the parties. This Agreement may not be assigned without the prior written consent of the other Party hereto.

(d) No Third-Party Beneficiaries. Nothing expressed or mentioned in this Agreement is intended or shall be construed to give any person or entity, other than the Parties and their respective successors and assigns, any legal or equitable right, remedy or claim under or in respect of this Agreement and any conditions and provisions hereof being intended to be and being for the sole and exclusive benefit of the parties hereto and their respective successors and assigns, and for the benefit of no other person or entity.

(e) Counterparts. This Agreement may be executed in any number of counterparts and by the Parties in separate counterparts (including by facsimile signature, Docusign or other form of electronic signature), each of which when so executed shall be deemed to be an original and all of which taken together shall constitute one and the same agreement. This Agreement may be executed and delivered by the Parties electronically, including by electronic mail, .pdf, Docusign, or other means of electronic delivery.

(f) Headings. The headings in this Agreement are for convenience of reference only and shall not limit or otherwise affect the meaning hereof.

(g) Governing Law; Choice of Venue.

(i) This Agreement shall be governed by and construed in accordance with the internal laws of the State of Delaware applicable to agreements made and to be performed within that state, without giving effect to any law or principals of law that would result in the application of the laws of any other jurisdiction.

(ii) Each Party (A) consents to submit itself to the personal jurisdiction of the Court of Chancery or other federal or state courts of the State of Delaware in the event any dispute arises out of this Agreement or the transactions contemplated by this Agreement, (B) agrees that it shall not attempt to deny or defeat such personal jurisdiction by motion or other request for leave from any such court, (C) agrees that it shall not bring any action relating to this Agreement or the transactions contemplated by this Agreement in any court other than the Court of Chancery or other federal or state courts of the State of Delaware, and each Party irrevocably waives the right to trial by jury and (D) irrevocably consents to service of process by a reputable overnight mail delivery service, signature requested, to the address of such Party's principal place of business or as otherwise provided by applicable law.

(h) Reimbursement. The Company shall reimburse the Marathon Parties for their reasonable out-of-pocket expenses, including the reasonable fees and expenses of counsel, incurred in connection with their engagement with the Company, the Nominations and the negotiation of, and all matters arising under this Agreement; provided, however, that such reimbursement shall not exceed $250,000.

9





(i) Severability. If at any time subsequent to the date hereof, any provision of this Agreement shall be held by any court of competent jurisdiction to be illegal, void or unenforceable, such provision shall be of no force and effect, but the illegality or unenforceability of such provision shall have no effect upon the legality or enforceability of any other provision in this Agreement.

(j) Interpretation and Construction. Each of the Parties acknowledges that it has been represented by counsel of its choice throughout all negotiations that have preceded the execution of this Agreement, and that it has executed the same with the advice of said independent counsel. Each Party and its counsel cooperated and participated in the drafting and preparation of this Agreement and the documents referred to herein, and any and all drafts relating thereto exchanged among the parties shall be deemed the work product of all of the parties and may not be construed against any Party by reason of its drafting or preparation. Accordingly, any rule of law or any legal decision that would require interpretation of any ambiguities in this Agreement against any Party that drafted or prepared it is of no application and is hereby expressly waived by each Party, and any controversy over interpretations of this Agreement shall be decided without regards to events of drafting or preparation. For purposes of this Agreement, the term including shall be deemed to be followed by the words without limitation.

(k) Entire Agreement. This Agreement contains the entire understanding of the Parties with respect to the subject matter hereof.

(l) Notices. Any notices, consents, determinations, waivers or other communications required or permitted to be given under the terms of this Agreement must be in writing and will be deemed to have been delivered: (i) upon receipt, when delivered personally; (ii) upon receipt, when sent by e-mail to the e-mail address for a Party set forth below; and (iii) one (1) business day after deposit with a nationally recognized overnight delivery service, in each case properly addressed to the Party to receive the same. The addresses for such communications shall be:

If to the Company or the Board:

e.l.f. Beauty, Inc. 570 10th Street Oakland, CA 94607 Attention: General Counsel Email: ***

with a copy (which shall not constitute notice) to:

Latham & Watkins LLP 140 Scott Drive Menlo Park, CA 94025 Attention: Tad Freese and Josh Dubofsky E-mail: Tad.Freese@lw.com and Josh.Dubofsky@lw.com

If to the Marathon Parties:

Marathon Partners Equity Management, LLC Attention: Mario Cibelli Email: ***

with a copy (which shall not constitute notice) to:

Olshan Frome Wolosky LLP 1325 Avenue of the Americas New York, NY 10019 Attention: Andrew Freedman E-mail: AFreedman@olshanlaw.com

10





(m) Termination. Unless earlier terminated as provided in this Agreement, upon the expiration of the Support Period, this Agreement shall immediately and automatically terminate in its entirety and no Party shall have any further rights or obligations under this Agreement; provided, however, (i) that this Section 8 shall survive any such termination and (ii) no Party shall be released from any breach of this Agreement that occurred prior to the termination of this Agreement.

[Signature Pages Follow]

11





IN WITNESS WHEREOF, each of the parties hereto has executed this Agreement, or caused the same to be executed by its duly authorized representative as of the date first above written.

E.L.F. BEAUTY, INC.

By: /s/ Scott Milsten Name: Scott Milsten Title: General Counsel

[Signature Page to Cooperation Agreement]





Marathon Partners Equity Management, LLC

By: /s/ Mario D. Cibell Name: Mario D. Cibelli Title: Managing Member

Marathon Partners L.P.

By: Marathon Partners Equity Management, LLC, its General Partner

By: /s/ Mario D. Cibell Name: Mario D. Cibelli Title: Managing Member

Marathon Focus Fund L.P.

By: Cibelli Research & Management, LLC, its General Partner

By: /s/ Mario D. Cibell Name: Mario D. Cibelli Title: Managing Member

Marathon Partners LUX Fund, L.P.

By: Cibelli Research & Management, LLC, its General Partner

By: /s/ Mario D. Cibell Name: Mario D. Cibelli Title: Managing Member

Cibelli Research & Management, LLC

By: /s/ Mario D. Cibell Name: Mario D. Cibelli Title: Managing Member

By: /s/ Mario D. Cibell Name: Mario D. Cibelli

[Signature Page to Cooperation Agreement]
Highlight the parts (if any) of this contract related to Anti-Assignment that should be reviewed by a lawyer. Details: Is consent or notice required of a party if the contract is assigned to a third party?

Exhibit 4.44 THIS LICENSE AND RESELLER AGREEMENT dated as of the October 30, 2018 is made BETWEEN: EHAVE, INC., a company incorporated under the laws of the Province of Ontario, Canada (Ehave); - and - COMPANION HEALTHCARE TECHNOLOGIES CORP, a company incorporated under the laws of the Province of Ontario (CHT) RECITALS: A. Ehave has developed a software platform that provides an end-to-end patient management solution to healthcare professionals and provides that platform to users as a service. B. CHT has developed a business model to bring a similar service that Ehave provides using the Ehave Platform for the domain of the animal market including companion animals (i.e. pets). C. The Parties desire to enter into this Agreement to enable CHT to pursue its business model whereby CHT will license and provide services in relation to companion and other animals using the Ehave Companion Solution under the terms and conditions contained herein. NOW THEREFORE, in consideration of the premises and the mutual agreements hereinafter set out herein and of other consideration (the receipt and sufficiency of which are acknowledged by each Party), the Parties covenant and agree as follows: 1. INTERPRETATION (a) Definitions In this Agreement and the schedules annexed hereto, the following terms shall have the respective meanings indicated below: Acceptance Criteria has the meaning ascribed to it in Section 3(d). Acceptance Period has the meaning ascribed to it in Section 3(d). Acceptance Procedures has the meaning ascribed to it in Section 3(d). Agreement means this license and reseller agreement and all Schedules, Appendixes and Exhibits attached hereto. Applicable Laws means any and all (i) laws, statutes, rules, regulations, by laws, codes, treaties, constitutions and ordinances, including Privacy Legislation (Laws), (ii) order, directive, judgment, decree, award or writ of any court (including a court of equity), arbitrator or arbitration panel, or any Governmental Authority or other body exercising adjudicative, regulatory, judicial or quasi-judicial powers, including any stock exchange (Orders), and (iii) policies, guidelines, standards, requirements, notices and protocols of any Governmental Authority (Policies); which are applicable to or govern CHT, Ehave or the transactions contemplated by this Agreement.

Source: EHAVE, INC., 20-F, 5/15/2019





Authentication ID means a security mechanism by which an Authorized User identifies herself or himself to the Ehave Companion Solution and gains access thereto, which security mechanism may include user identification, passwords, digital certificates or any other similar process mechanism for authentication and recognition as determined by Ehave from time to time. Authorized User means an individual who an End User has authorized to access and use CHT's services, which includes the use of the Ehave Companion Solution. Business Day means any calendar day except for Saturday or Sunday or any statutory holiday observed in the Province of Ontario. CHT Developments has the meaning ascribed to it in Section 4(a). CHT Indemnified Parties has the meaning ascribed to it on Section 16(a). CHT Marks means the names, trademarks, trade names, service marks, designs and logos of CHT. Claim has the meaning ascribed to it in Section 16(a). Competitive Transaction has the meaning ascribed to it in Section 2(d). Confidential Information means this Agreement, the Ehave Companion Solution, End User Data and all ideas, designs, business models, databases, drawings, documents, diagrams, formulas, test data, marketing, financial or personnel data, sales information, customer or supplier information, including information provided by such customers or suppliers, or any other information already furnished and to be furnished or made available by one Party to the other, whether in oral, written, graphic or electronic form including any such information exchanged during informational sessions designated as confidential, including, without limitation, information concerning a Party's actual and potential customers and other Intellectual Property Rights of such Party, provided, however, that Confidential Information shall not include any data or information: (i) that, at the time of disclosure, is in or, after disclosure, becomes part of the public domain, through no act or failure on the part of the receiving Party, whether through breach of this Agreement or otherwise; (ii) that, prior to disclosure by the disclosing Party, was already in the possession of the receiving Party, as evidenced by written records kept by the receiving Party in the ordinary course of its business, or as evidenced by proof of actual prior use by the receiving Party; (iii) independently developed by the receiving Party, by Persons having no direct or indirect access to the disclosing Party's Confidential Information provided that the receiving Party provides clear and convincing evidence of such independent development; (iv) which, subsequent to disclosure, is obtained from a third Person: (A) who is lawfully in possession of such information; (B) who is not in violation of any contractual, legal, or fiduciary obligation to either Party, as applicable, with respect to such information; and (C) who does not prohibit either Party from disclosing such information to others; or (v) is further disclosed with the prior written consent of the disclosing Party, but only to the extent of such consent. Effective Date means the date first written above. Ehave Companion Solution means the Ehave Platform, as modified, adapted and customized, as provided herein, the specifications of which are set out in Schedule 1.

2.

Source: EHAVE, INC., 20-F, 5/15/2019





Ehave Platform means the Software, Ehave Server and such devices and peripherals physically located with the Ehave Server, including all computer hardware, software, network elements, and electrical and telecommunications infrastructure located behind the Point of Access. Ehave Server means that computer server located at Ehave's premises, or a third party provider of hosting and/or network services, that houses the Software. End User means CHT's customers who have entered into a subscription agreement with CHT for CHT services, which services include the use of the Ehave Companion Solution. End User Data means collectively any data, files, documentation or other information (including personal information) that an End User or any of its Authorized Users may: (i) upload to the Ehave Companion Solution; and/or (ii) have processed through the use of the Ehave Companion Solution, and includes any data or output resulting from or derived from such use. Escrow Agent has the meaning ascribed thereto in Section 12(a). Escrow Agreement has the meaning ascribed thereto in Section 12(a). Field of Use means indications and outcomes related to any companion and other animals. Governmental Authority means any domestic, foreign or supranational government, whether federal, provincial, state, territorial or municipal; and any governmental agency, ministry, department, tribunal, commission, bureau, board or other instrumentality, including international institutions, exercising or purporting to exercise legislative, judicial, regulatory or administrative functions of, or pertaining to, government. Implementation Plan has the meaning ascribed to it in Section 3(a). Intellectual Property means any property, tangible or intangible, that may be subject to Intellectual Property Rights, including without limitation, ideas, formulae, algorithms, concepts, techniques, processes, procedures, approaches, methodologies, plans, systems, research, information, documentation, data, data compilations, specifications, requirements, designs, diagrams, programs, inventions, technologies, software (including its source code), tools, products knowledge, know-how, including without limitation, trade secrets, and other materials or things. Intellectual Property Rights means (a) any and all proprietary rights anywhere in the world provided under (i) patent law; (ii) copyright law, including moral rights; (iii) trademark law; (iv) design patent or industrial design law; (v) semiconductor chip or mask work law; (vi) trade secret law; (vii) privacy law; or (viii) any other statutory provision or common law principle applicable to this Agreement which may provide a right in either (A) Intellectual Property; or (B) the expression or use of Intellectual Property; and (b) any and all applications, registrations, licenses, sub-licenses, franchises, agreements or any other evidence of a right in any of the foregoing. Objectionable Content means content that infringes any Applicable Laws or third party rights, and content which is obscene, indecent, pornographic, seditious, defamatory, threatening, liable to incite racial hatred, menacing, blasphemous, misleading, deceptive or in breach of any person's Intellectual Property Rights. Party means either Ehave or CHT; and Parties means both of them. Person means any individual, estate, sole proprietorship, firm, partnership, unincorporated association, unincorporated syndicate, unincorporated organization, limited liability company, corporation, body corporate, trustee, trust, Governmental Authority or other entity or organization and includes any successor to any of the foregoing.

3.

Source: EHAVE, INC., 20-F, 5/15/2019





Point of Access means Ehave's, or its subcontractor's, border router, which is used to establish connectivity from the Ehave Platform to Ehave's, or its subcontractor's, Internet provider, or the public Internet. Royalties means the fees, charges and other amounts to be paid by CHT to Ehave for the rights granted hereunder and which amounts are set out in Schedule 6. Security Requirements means those safeguards and controls set out in Schedule 5. Software means Ehave's proprietary patient and data management software and any related documentation, as modified for use in the animal (including companion animal) and veterinary industry. Source Code means the human-readable form of a computer instruction, including, but not limited to, related system documentation, flow charts, all comments and any procedural code and a description of the procedure for generating object code, all of a level sufficient to enable a programmer reasonably fluent in the programming language in which the Software was written to understand, build, operate, support, maintain and develop modifications, upgrades, updates, adaptations, enhancements, new versions, and other derivative works and improvements of, and to develop computer programs compatible with, the Software. Specifications has the meaning ascribed to it in Section 3(a).Subscription Agreement has the meaning ascribed to it in Section 5(b). Term has the meaning ascribed to it in Section 9. Territory means any jurisdiction in the World where the use of the Ehave Companion Solution for the intended purpose herein is permitted under Applicable Law. Transition out Period has the meaning ascribed to it in Section 10(f). Transition-out Services has the meaning ascribed to it in Section 10(f). Virus means a piece of code usually (but not necessarily) disguised as something else that causes some unexpected and, for the victim, usually undesirable, event and which is designed so that it may automatically spread to other computer users; the term 'Virus' will also be deemed to include worms, cancelbots, trojan horses, harmful contaminants (whether self-replicating or not) and nuisance causing or otherwise harmful applets. (b) Headings; Extended Meanings The division of this Agreement into articles, sections, schedules and other subdivisions, and the inclusion of headings are for convenience of reference only and shall not affect the construction or interpretation of this Agreement. The headings in the Agreement are not intended to be full or precise descriptions of the text to which they refer. Unless something in the subject matter or context is inconsistent therewith, references herein to Articles and Sections are to Articles and Sections of this Agreement. The word including or include(s) means including without limitation or include(s) without limitation. (c) Currency Unless otherwise specified, all references to monetary amounts, including the symbol $, are in respect of Canadian currency.

4.

Source: EHAVE, INC., 20-F, 5/15/2019





(d) Exhibits and Schedules The following Schedules are a part of and are integral to this Agreement: Schedule 1 - Ehave Companion Solution Specifications Schedule 2 - Development and Implementation Plan Schedule 3 - Support Procedures Schedule 4 - Service Level Commitments Schedule 5 - Security Requirements Schedule 6 - Royalties and Early Termination Fee Schedule 7 - Source Code Escrow (e) Entire Agreement This Agreement, together with any other documents to be delivered pursuant hereto, constitutes the entire agreement between the Parties pertaining to the subject matter hereof and supersedes all prior agreements, negotiations, discussions and understandings, written or oral, between the Parties. Except as expressly provided in this Agreement, there are no representations, warranties, conditions other agreements or acknowledgements, whether direct or collateral, express or implied, that form part of or affect this Agreement. The execution of this Agreement has not been induced by, nor do either of the Parties rely upon or regard as material, any representations, warranties, conditions, other agreements or acknowledgements not expressly made in this Agreement or in the other documents to be delivered pursuant hereto. (f) Governing Law: This Agreement shall be governed by, and construed and enforced in accordance with, the laws in force in the Province of Ontario (excluding any conflict of laws rule or principle which might refer such construction to the laws of another jurisdiction). The Parties hereto agree to submit to the exclusive jurisdiction of the courts of the Province of Ontario and waive any objection relating to improper venue or forum non conveniens to the conduct of any proceeding in any such court. (g) Severability: In the event that any provision (or any portion of a provision) of this Agreement shall for any reason be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable for any reason, such invalidity, illegality or unenforceability shall not affect any other provision hereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision (or portion of a provision) had never been contained herein in regards to that particular jurisdiction. 2. APPOINTMENT AND LICENSE GRANT (a) Exclusive Appointment Ehave hereby appoints CHT, and CHT hereby accepts the appointment, to act as Ehave's reseller of the use of the Ehave Companion Solution within the Field of Use in the Territory for the duration of the Term solely in accordance with the terms and conditions of this Agreement. Subject to Section 2(e), the foregoing appointment is exclusive such that Ehave shall not appoint any other Person to, nor may Ehave itself, sell or resell the use of the Ehave Companion Solution within the Field of Use anywhere in the Territory.

5.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Grant by Ehave Subject to the terms and conditions of this Agreement commencing as of the Effective Date and for the duration of the Term and any Transition-out Period, Ehave hereby grants to CHT a non-transferable (except as permitted under Section 20(f)), right to: (i) sub-license the use of the Ehave Companion Solution within the Field of Use in the Territory to End Users and their respective Authorized Users, including in operation or by interfacing with other software, hardware, systems, networks and services, in accordance with and subject to the provisions of CHT's Subscription Agreement; and (ii) use the Ehave Companion Solution to support its licensed End Users. Subject to Section 2(e), the grant set out in Clause 2(b)(i) is exclusive such that Ehave shall not license any other Person to, nor may Ehave itself, license, sub-license the use of, or provide services similar to, the Ehave Companion Solution within the Field of Use anywhere in the Territory. (c) Restrictions on Use Any rights not granted herein are strictly reserved by Ehave. CHT shall not, and shall not permit others to, reverse engineer, decompile, disassemble or translate any software used by Ehave to provide the Ehave Companion Solution, or otherwise attempt to view, display or print such software, including its Source Code, except as permitted herein. (d) Prohibition on Competitive Solutions For so long as the appointment set out in Section 2(a) is exclusive, CHT shall not enter into an agreement (a Competitive Transaction) with any other Person related to the license, sub-license, sale, resale or provide service, solutions, goods or products, that are substantially similar to or competitive with the Ehave Companion Solution. For clarity, a Competitive Transaction shall not include an agreement for use, integration or interfacing, or co-marketing, of the Ehave Companion Solution with other services, solutions, devices, goods or products, where such other services, solutions, devices, goods or products do not contain the same or similar functionality of the Ehave Companion Solution, but provides for a complementary solution. (e) Conversion to Non-Exclusive Notwithstanding anything to the contrary contained herein, the exclusive appointment and license set out in Sections 2(a) and 2(b) shall become non-exclusive if: (i) at any time during the Term hereof, CHT breaches Section 2(d) as determined by arbitration in accordance with Section 19(c) or by a final non-appealable judgment of a court of competent jurisdiction; or (ii) at any time after November 1, 2010 CHT fails to achieve annual revenues of $500,000. (f) No Franchise Agreement The Parties to this Agreement are independent contractors and nothing in this Agreement shall be deemed or constructed as creating a joint venture, partnership, agency relationship, or franchise between Ehave and CHT. Neither Party, by virtue of this Agreement, will have any right, power or authority to act or create an obligation, express or implied, on behalf of the other Party. Each Party assumes responsibility for the actions of their personnel under this Agreement and will be solely responsible for their supervision, daily direction and control, wage rates, withholding income taxes, Canada Pension Plan contributions, employment insurance premiums, disability benefits, or the manner and means through which the work under this Agreement will be accomplished. Except as provided otherwise in this Agreement, CHT has the sole discretion to determine CHT's methods of operation, CHT's accounting practices, the types and amounts of insurance CHT carries, CHT's personnel practices, CHT's advertising and promotion, CHT's customers and CHT's service areas and methods. The relationship created hereby between the parties is solely that of supplier and reseller, and licensor and licensee.

6.

Source: EHAVE, INC., 20-F, 5/15/2019





3. DEVELOPMENT AND IMPLEMENTATION OF THE COMPANION SOLUTION (a) Specifications and Implementation Attached hereto as Schedule 1 are the business requirements and technical specifications of the Ehave Companion Solution (the Specifications). Attached hereto as Schedule 2 is the development and implementation plan (the Implementation Plan), which sets out the procedures and obligations of each of the Parties and the key milestones and timelines in relation to the development and implementation of the Ehave Companion Solution. The Parties acknowledge that at the time of execution of this Agreement that the Specifications and Implementation Plan may not have been fully developed, but that the creation of the Specifications and development of the detailed Implementation Plan will be the first step in respect of the development and implementation of the Ehave Companion Solution, in which case, once approved by the Parties in writing, the Specifications and Implementation Plan so developed will be attached hereto and shall replace Schedules 1 and 2 respectively. Once finalized the Specifications and Implementation Plan may not be changed or modified by either Party, except in accordance with the procedures set out in Section 3(c). (b) Obligations Each of Ehave and CHT shall perform, at their own expense (or as otherwise set out in Schedule 6), their respective obligations and responsibilities set out in the Implementation Plan as necessary to accomplish the development and implementation of the Ehave Companion Solution in accordance with the milestones and timelines set out therein. CHT acknowledges that the development and implementation of the Ehave Companion Solution requires decisions and input from CHT and for CHT to perform its obligations thereunder in a timely manner. In the event that CHT delays in providing such decisions, input or performance of its obligations, the development and implementation of the Ehave Companion Solution shall be correspondingly delayed. Subject to the foregoing, Ehave acknowledges that time is of the essence with respect to its obligations hereunder and that prompt and timely performance of all such obligations, including all development and implementation dates, timetables, project milestones and other requirements in this Agreement is strictly required. Once the implementation of the Ehave Companion Solution is completed, Ehave shall notify CHT of such completion and that the Ehave Companion Solution is ready for testing in accordance with Section 3(d).

7.

Source: EHAVE, INC., 20-F, 5/15/2019





(c) Change Control Process Either Party may request additions, deletions or amendments in respect of the development and implementation of the Ehave Companion Solution (Change). Changes shall be requested in writing signed by an authorized representative of the Party requesting the Change (Change Request). Ehave shall have no obligation to perform, and CHT shall have no obligation to pay for, services related to any proposed modification or change unless both Parties have agreed to the modifications or changes in writing in accordance with the procedures set forth herein. The Change Request shall include a reasonably detailed description of the scope and nature of the requested Change. If CHT desires a Change, Ehave shall evaluate the feasibility of such change as it relates to the proposed Field of Use. As soon as reasonably possible after receipt of CHT's request, Ehave agrees to provide CHT with a written estimate of the cost, if any, of and the timing to implement the requested Changes as well as any additional terms and conditions related to such Changes. The costs, if any, associated with the development of such estimate shall be borne by CHT. Upon CHT's approval in writing of the cost estimate and any additional terms and conditions related to such Changes, including delivery dates and payment terms provided by Ehave, the Parties shall revise the Specifications and Implementation Plan and shall replace the Specifications and Implementation Plan attached hereto as Schedules 1 and 2, and Ehave shall develop and implement the Change as so agreed. Changes shall be subject to acceptance testing by CHT prior to being deployed into production in accordance with procedures described in Section 3(d) or as otherwise agreed by the parties in writing. Ehave shall not refuse to accept a CHT Change request unless it is unable to make the Change requested using commercially reasonable efforts, in which event Ehave will provide an explanation to CHT; or Ehave and CHT fail to agree on the terms and conditions related to the performance of such Change, including the costs, if any. If a mutually acceptable resolution is not reached in respect of a CHT Change request, the Parties may submit the issue to mediation pursuant to Section 19(b). (d) Acceptance The criteria (Acceptance Criteria) which the Ehave Companion Solution is to meet and the procedures by which such criteria are to be tested (Acceptance Procedures) shall be set out in the Implementation Plan and shall follow the requirements set out in this Section 3(d). Once notified by Ehave that the Ehave Companion Solution is ready for acceptance testing, CHT shall perform the tests as set out in the Acceptance Procedures. Unless otherwise set out in the Acceptance Procedures, CHT shall have ten (10) Business Days to perform the acceptance tests as set out in the Acceptance Procedures and to provide Ehave written notice of acceptance or non-acceptance of the Ehave Companion Solution (the Acceptance Period). CHT shall not refuse to accept the Ehave Companion Solution unless all or one or more portions of the Solution fail to perform, in any material respect, in accordance with the Acceptance Criteria. Any notice of non- acceptance shall describe the material failure of the Ehave Companion Solution in reasonable detail and CHT shall provide Ehave with reasonably detailed documentation and explanations, together with underlying data, to substantiate the failure and to reasonably assist Ehave in its efforts to diagnose and correct the failure. If CHT gives notice to Ehave of non-acceptance of the Ehave Companion Solution then Ehave shall investigate the reported failure in good faith and correct same, and if the engagement is on a fixed fee basis at no additional cost to CHT, within fifteen (15) Business Days unless an extension is granted by CHT. If, within such fifteen (15) Business day period (or extended period, as applicable), Ehave corrects the failure, then Ehave shall give written notice to CHT certifying that the failure has been corrected, and another Acceptance Period of the same duration as the initial Acceptance Period shall begin and shall be governed by the provisions of this Section 3(d) upon delivery of the corrected Ehave Companion Solution to CHT. If the Acceptance Procedures were conducted three (3) times in respect of the initial implementation of the Ehave Companion Solution, and the eHAve Companion Solution failed to pass the Acceptance Criteria on the third (3rd) try, then, at the discretion of either Party, Ehave may continue to fix the problem, or terminate this Agreement in which case, CHT shall promptly return to Ehave all copies of the Ehave Companion Solution, including the Specifications and any other items delivered to CHT by Ehave thereunder and Ehave shall promptly refund to CHT any monies paid by CHT in respect of the initial development and implementation of the Ehave Companion Solution. If the Acceptance Procedures were conducted three (3) times in respect of a Change, and the Change failed to pass the Acceptance Criteria on the third (3rd) try, then, at the discretion of CHT, Ehave may continue to fix the problem, or terminate the performance of the development of the Change, in which case CHT shall promptly return to Ehave all copies of the Change, including the Specifications thereto and Ehave shall promptly refund to CHT any monies paid by CHT in respect of the development and implementation of the Change.

8.

Source: EHAVE, INC., 20-F, 5/15/2019





(e) Deployment Once CHT provides Ehave written notice of acceptance, Ehave will deploy the Ehave Companion Solution or Change, as applicable, by putting the Ehave Companion Solution or Change into production in accordance with, and within the timelines set out, in the Implementation Plan or Change Request, as the case may be. (f) Branding The Ehave Companion Solution may, in the sole discretion of CHT, be branded, marketed, advertised, promoted and sublicensed under CHT Marks. For such purpose, CHT hereby grants to Ehave a non-exclusive, royalty-free, revocable, limited license during the Term and Transition-out Period and within the Territory to use, reproduce, publish and display the CHT Marks solely in connection with the operation of the Ehave Companion Solution for and on behalf of CHT and End Users. Ehave agrees that its use of any CHT Marks will comply with CHT's branding guidelines to the extent made available by CHT to Ehave from time to time and will enure to the benefit of CHT. The CHT Marks are proprietary to CHT and nothing in this Agreement constitutes the grant of a general license for their use. Other than as expressly set forth herein, Ehave does not acquire any right, title or interest in or to any CHT Marks or the goodwill associated therewith. CHT reserves any and all rights in and to the CHT Marks not expressly granted herein. 4. CHT DEVELOPMENTS (a) Development From time to time, CHT may request Ehave to develop functionality that is separate from, but interfaces with the Ehave Companion Solution (the CHT Developments). Any such development effort shall be subject to a separate services agreement between the Parties which will set out the respective obligations of the Parties regarding the development and deployment of any CHT Developments, including without limitation assignment or transfer of any rights that Ehave may have in such CHT Developments. (b) APIs If CHT desires a third party to develop any CHT Developments, Ehave shall provide to CHT the specifications of the application program interfaces to permit CHT or such other third party to develop the CHT Developments so that it may inter-operate with the Ehave Companion Solution. (c) License If CHT requires Ehave to host the CHT Developments, then CHT hereby grants to Ehave a royalty-free, non-exclusive, non-transferable, limited right and licence during the Term hereof to use the CHT Developments solely for the purpose of enabling its operation for CHT and its End Users' purposes. 5. GENERAL PERFORMANCE OBLIGATIONS (a) Marketing CHT shall, in good faith and at its own expense: (i) market, advertise, promote and re-license the use of the Ehave Companion Solution to End Users located in the Territory consistent with good business practice, provided that CHT shall have full discretion as to where in the Territory it chooses to do so at any time and from time to time;

9.

Source: EHAVE, INC., 20-F, 5/15/2019





(ii) develop and execute a marketing plan sufficient to fulfil its obligations under this Agreement; (iii) have sufficient knowledge of the industry and solutions competitive with the Ehave Companion Solution (including specifications, features and benefits) so as to be able to explain in detail to the End Users: A. the material differences between the Ehave Companion Solution and competing solutions; and B. information on standard protocols and features of the Ehave Companion Solution; (iv) market, advertise, promote and provide the Ehave Companion Solution and conduct business in a manner that at all times reflects favourably on the Ehave Companion Solution and, subject to Section 3(f), the good name, goodwill and reputation of Ehave; and (v) maintain books, records and accounts of all transactions and activities covered by this Agreement and permit reasonable examination thereof by Ehave and its representatives in accordance with this Agreement. (b) Provision to End Users CHT shall require each End User to enter into and execute a subscription agreement in a form and substance satisfactory to Ehave and CHT, acting reasonably, and which contains provisions similar to Ehave's collaboration agreement for the use of the Ehave solution (the Subscription Agreement). Ehave shall be a third party beneficiary hereunder, but shall not have any obligations to the End User thereunder. (c) End User Data Pursuant to the Subscription Agreement, CHT shall obtain from each End User the right to and hereby grants, effective upon the execution and delivery of such End User's Subscription Agreement, to Ehave: (i) a royalty-free, non-exclusive, non-transferable, limited right and licence during the term of such Subscription Agreement to use, copy, store and display the End User Data solely for the purpose of enabling Ehave to operate the Ehave Companion Solution for such End User and as may be necessary for the purpose of enabling Ehave to provide support services in accordance with this Agreement; and (ii) a royalty-free, non-exclusive, limited, perpetual right and license to use, copy, store and display End User Data on an aggregated and anonymous basis and so as not to permit the identification of any End User or individual for the sole purpose of improving or developing enhancements to the Ehave Companion Solution , provided that Ehave shall not have any right to use, commercialize or exploit such End User Data in any other manner or for any other purpose. Except for the limited license expressly provided in Section 5(c), nothing contained in this Agreement shall be construed as granting to Ehave or any third party any right, title, or interest in or to any End User Data. Without limiting the foregoing, Ehave agrees that it shall not (i) modify, alter or commercially exploit any End User Data; or (ii) distribute or sell, rent, lease, license or otherwise make any End User Data available to any third party (other than the particular End User to whom the End User Data pertains and its Authorized Users).

10.

Source: EHAVE, INC., 20-F, 5/15/2019





(d) Authority to Perform Under this Agreement Each Party shall, at its own expense, obtain and maintain required certifications, credentials, licences and permits necessary to conduct business in accordance with this Agreement. CHT shall obtain all necessary licenses, permits, certifications and credentials to conduct its business. (e) End User Support On and after the launch of the Ehave Companion Solution, CHT shall, at its own expense, ensure that an adequate number of trained, capable and qualified technical personnel with sufficient knowledge of the Ehave Companion Solution are available to provide first line support to assist End Users. If CHT's support personnel are unable to resolve any trouble tickets from an End User, CHT may escalate the trouble ticket to Ehave in accordance with the support procedures set out in Schedule 3. On and after the launch of the Ehave Companion Solution, Ehave shall ensure that an adequate number of trained, capable and qualified technical personnel with sufficient knowledge of the Ehave Companion Solution are available to provide support in accordance with the support procedures set out in Schedule 3. (f) Government Approval If, at any time during the Term, any notification, registration or approval is required to give legal effect in any applicable jurisdiction to this Agreement or the transactions contemplated under this Agreement, CHT shall: (i) immediately take whatever steps may be necessary to properly notify, register or obtain approval; (ii) be responsible for any charges incurred in connection with notifying, registering or obtaining this approval; and (iii) keep Ehave currently informed of its efforts regarding this Section 5(f). Ehave is not obligated to provide access to the Ehave Companion Solution in a particular jurisdiction under this Agreement until CHT has provided Ehave with satisfactory evidence that: (i) this approval, notification or registration is not required or that (ii) it has been obtained. At CHT's cost and expense, Ehave shall provide reasonable assistance and cooperation to CHT as CHT may reasonably request in its efforts to obtain or provide any such approval, notification or registration, provided that, CHT shall at all times retain full discretion as to where in the Territory it chooses to market, promote, advertise and/or sublicense the Ehave Companion Solution. (g) Prohibited Acts Notwithstanding anything to the contrary in this Agreement, neither CHT nor CHT personnel shall: (i) make any representations, conditions, warranties, guarantees, indemnities, similar claims or other commitments: A. actually, apparently or ostensibly on behalf of Ehave, or B. to any End User regarding the Ehave Companion Solution, which representations, conditions, warranties, guarantees, indemnities, similar claims or other commitments are additional to or inconsistent with any then-existing representations, conditions, warranties, guarantees, indemnities, similar claims or other commitments in this Agreement or any written or electronic documentation provided by Ehave to CHT; or

11.

Source: EHAVE, INC., 20-F, 5/15/2019





(ii) engage in any unfair, competitive, misleading or deceptive practices respecting Ehave, Ehave's Trade-marks or the Ehave Companion Solution, including any product disparagement or bait-and-switch practices. 6. EHAVE COMPANION SOLUTION (a) Provision and Access to Ehave Companion Solution Once deployed, Ehave shall operate, support and maintain the Ehave Companion Solution in accordance with the terms of this Agreement, including the Support Procedures set out in Schedule 3, the Service Level Commitments set out in Schedule 4 and the Security Requirements set out in Schedule 5. Access to the Ehave Companion Solution may be through a secure connection with the public Internet. CHT acknowledges and agrees that Ehave is not responsible or liable for any communication over the public Internet. (b) Security Requirements Ehave shall implement and maintain those safeguards and controls set out in Schedule 5 to deter and for the detection, prevention and correction of any unauthorized intrusion, access or use of the Ehave Companion Solution, as well as to protect against any loss, theft or unauthorized access, use, disclosure, copying, or modification of End User Data. CHT acknowledges and agrees, and shall obtain such acknowledgement and agreement from its End Users, that notwithstanding the Security Requirements, such methods and procedures may not prevent unauthorized electronic intruders to access the Ehave Companion Solution through the Internet or through other form of electronic communication. If such unauthorized electronic intruders are able to bypass Ehave's security protocols, firewall and safeguards, such unauthorized electronic intruder may change, delete or otherwise corrupt the contents and data contained in the Ehave Server, including any End User Data. Except for the maintenance of appropriate firewall and safeguards in compliance with the Security Requirements, which are designed to frustrate access from unauthorized electronic intruders, Ehave shall not be liable to CHT or to any of its End users, and hereby disclaims responsibility, with respect to any action, destructive or otherwise, by any unauthorized electronic intruder. (c) Maintenance From time to time, it will be necessary for Ehave to perform maintenance on the Ehave Companion Solution. Such maintenance includes routine maintenance to ensure the continued provision of the Ehave Companion Solution or upgrading, updating or enhancing the Ehave Companion Solution. Ehave shall use its commercially reasonable efforts to perform such maintenance at such times within the designated maintenance windows set forth in Schedule 3 to minimize the impact of any downtime of the Ehave Platform to CHT and its End Users. To the extent Ehave is able, Ehave shall notify CHT at least 48 hours in advance of any scheduled maintenance by sending an email to the designated CHT Service Manager of the scheduled maintenance time and the anticipated duration of such maintenance. (d) Changes to Service Ehave may, at any time, with or without written notice (except in cases where such change may affect the manner in which the Services are delivered, in which case, Ehave shall use reasonable efforts to provide advance written notice, but in any event as soon as reasonably possible thereafter) to CHT (i) make changes to the Ehave Companion Solution that are necessary to comply with applicable safety, security or other statutory requirements or orders from applicable Governmental Authorities; (ii) supplement or make changes to its user documentation and to its rules of operations, access procedures, security and privacy procedures and policies, provided such changes do not materially adversely affect CHT or its End Users; and (iii) change the components, type and location of the Ehave Platform, provided that such changes do not adversely affect the performance, features, functionality or security of the Ehave Companion Solution.

12.

Source: EHAVE, INC., 20-F, 5/15/2019





(e) Authentication IDs CHT shall, and shall require its End Users to, control and maintain the security of all Authentication IDs. As between CHT and Ehave, CHT shall be solely responsible for all instructions, commitments and other actions or communications taken under any of CHT's Authentication IDs. CHT shall promptly report to Ehave any errors or irregularities in the Ehave Companion Solution or the Ehave Platform or any unauthorized use of any part thereof that come to CHT's attention and inform Ehave immediately if CHT becomes aware that any Authentication ID becomes known to any third person who is not authorized to possess such password. (f) End User Data CHT acknowledges and agrees that Ehave: (i) will not be responsible for the accuracy, completeness or adequacy of any End User Data or the results generated from any End User Data uploaded to and processed by the Ehave Companion Solution in accordance with the Specifications; (ii) has no control over any End User Data or the results therefrom; (iii) does not purport to monitor End User Data; and (iv) shall not be responsible to back up or maintain any back up of the End User Data or portion thereof. (g) Viruses If Ehave, in its absolute discretion, forms the view that any End User Data or any other information or files uploaded by CHT or any of its End User and their Authorized Users contains or includes a Virus or is reasonably considered Objectionable Content, Ehave may remove such End User Data, information or file from the Ehave Companion Solution and take such other action as Ehave deems necessary to protect the integrity and operation of the Ehave Companion Solution. Any reasonable costs associated with such removal may be charged by Ehave to CHT. Ehave shall notify CHT of its actions under this Section 6(g) as soon as reasonably possible. 7. ROYALTIES AND PAYMENT (a) Royalties The Royalties and payment terms are as set out in Schedule 6. The Royalties do not include applicable taxes. CHT agrees to pay the Royalties and applicable taxes in accordance with the payment terms as set out in Schedule 6. (b) Taxes: CHT shall pay any and all applicable taxes, however designated or incurred, which are payable by it pursuant to Applicable Law as a result of or otherwise in connection with the transactions contemplated in this Agreement including, without limitation, federal, provincial and local, excise, sales, use, goods and services, harmonized, value added and any similar taxes, except for any taxes based on Ehave's net income. (c) Interest on Late Payments: Where CHT fails to pay any amount in accordance with the payment terms set out in Schedule 6, Ehave shall have the right, in addition to any other rights or remedies available to it, to charge, and CHT shall pay, interest on such overdue amounts at the rate of 1% per month calculated daily, compounded monthly (12.68% per annum) both before and after any court judgement in respect of the same from the date such payment was due.

13.

Source: EHAVE, INC., 20-F, 5/15/2019





8. AUDIT RIGHTS (a) Ehave Right to Audit CHT will provide Ehave and its representatives, auditors and inspectors (Auditors) upon ten (10) Business Days prior written notice with reasonable access, during business hours, to all facilities, systems and assets used by CHT, to CHT personnel and subcontractors and to all relevant CHT books and records, in each case, to the extent relevant to this Agreement, in order to conduct appropriate audits, examinations and inspections (Audits) to: (i) verify compliance with the requirements set out in this Agreement; and (ii) verify the Royalty calculations. (b) Principles Regarding Audits CHT shall provide to Ehave and its Auditors any assistance they may reasonably require to conduct such Audits. Audits may be conducted once a calendar year, provided that the foregoing limit shall not apply where an audit discovered an overcharge of 5% or more, in which case, Ehave may conduct another audit sooner. No period shall be audited more than once. Costs incurred by Ehave in connection with any audit or inspection conducted shall be borne by Ehave. Notwithstanding the foregoing, if an Audit reveals that CHT underpaid Ehave for any Royalties hereunder, by more than five percent (5%) of the total Royalties paid during the period being audited, CHT shall promptly reimburse Ehave for all reasonable third party expenses incurred by Ehave in connection with such Audit. In all cases CHT shall promptly pay Ehave in full for any underpayments revealed by an Audit. All information obtained by Ehave and its Auditors during any such Audit shall be kept confidential and shall be considered CHT's Confidential Information. Ehave shall impose confidentiality obligations on its Auditors that are substantially similar to those under Section 13 and shall be responsible for any breach of confidentiality by its Auditors. (c) Records CHT shall keep detailed records and books of account with supporting vouchers, invoices and other documentation showing all expenditures, charges and related calculations of whatsoever nature made by it in the performance of its obligations under this Agreement. CHT shall retain such records for the greater of: (i) three (3) years; or (ii) the period required by Applicable Laws. (d) Security Audit On an annual basis, Ehave shall conduct and provide CHT the results of an audit conducted in accordance with the Statement on Standards for Attestation Engagements (SSAE) No. 18, Service Organization Control (SOC) 2 Report type audit or similar audits in respect of its operations. Ehave shall also provide CHT written notice and detail of any deficiencies that Ehave's auditors (whether internal or external) found through the conduct of such audits and the remediation efforts that Ehave shall undergo to rectify such deficiencies. Ehave shall promptly rectify any deficiencies identified that may materially and adversely impact the Ehave Companion Solution or End User Data, and shall provide CHT with such information as CHT may reasonably request from time to time with respect to its security controls including any remediation efforts undertaken to rectify any deficiencies. 9. TERM This term of this Agreement and the rights and obligations of the Parties hereto shall commence as of the Effective Date and shall continue in perpetuity (the Term), unless terminated earlier in accordance with the provisions contained herein.

14.

Source: EHAVE, INC., 20-F, 5/15/2019





10. SUSPENSION AND TERMINATION (a) Suspension of Services: Subject to the provisions of this Section, in the event that CHT does not pay the Royalties or any portion thereof, when due, Ehave may immediately suspend CHT's and each of its End Users' right to access and use the Ehave Companion Solution. However, Ehave shall not suspend CHT's or its End Users' right to access and use the Ehave Companion Solution or any End User Data by reason of CHT's good faith withholding of any payment or amount, or in the event of any payment dispute between the parties arising under or concerning this Agreement, in each case, unless and until such dispute is resolved pursuant to Section 19, provided that CHT shall have a period of five (5) Business Days to pay any amount agreed to in settlement or determined by arbitration pursuant to Section 19 to be payable by it. (b) CHT's Right to Terminate: Subject to Sections 10(e) and 10(g), CHT may terminate this Agreement and the rights granted hereunder, in whole or in part, without prejudice to enforcement of any other legal right or remedy (including any express termination right set forth elsewhere in this Agreement), immediately upon giving written notice of such termination if Ehave: (i) breaches any material provision of this Agreement and such breach continues for a period of twenty (20) Business Days after delivery of a written notice by CHT requiring Ehave to correct such failure; or (ii) becomes or is adjudicated insolvent or bankrupt, admits in writing its inability to pay its debts as they mature, or makes an assignment for the benefit of creditors; or Ehave applies for or consents to the appointment of any receiver, trustee or similar officer for it or for all or any substantial part of its property; or such receiver, trustee or similar officer is appointed without the consent of Ehave; or Ehave institutes any bankruptcy, insolvency, reorganization, moratorium, arrangement, readjustment or debt, dissolution, liquidation or similar proceeding relating to it under the laws of any jurisdiction, or any such proceeding is instituted against Ehave and is not dismissed within sixty (60) Business Days; or any judgment, writ, warrant or attachment or execution of similar process is issued or levied against a substantial part of Ehave's property and remains unsatisfied for sixty (60) Business Days. In addition, CHT may terminate this Agreement and the rights granted hereunder, in whole or in part, and without prejudice to enforcement of any other legal right or remedy (including any express termination right set forth elsewhere in this Agreement), at any time without cause, by providing at least thirty (30) Business Days prior written notice to Ehave, but subject to payment of a termination fee equal to an amount set out in Schedule 6. (c) Ehave's Right to Terminate: Subject to Sections 10(e) and 10(g), Ehave may terminate this Agreement and the rights granted hereunder without prejudice to enforcement of any other legal right or remedy, immediately upon giving written notice of such termination if CHT: (i) fails to pay in full any sum owing by it under this Agreement by the due date thereof (other than any sum the payment of which is disputed by CHT in good faith and withheld pending resolution of such dispute in accordance with Section 19) and such failure continues for a period of ten (10) Business Days after delivery of a written notice by Ehave requiring CHT to correct such failure;

15.

Source: EHAVE, INC., 20-F, 5/15/2019





(ii) breaches any other material provision of this Agreement and such breach continues for a period of twenty (20) Business Days after delivery of a written notice by Ehave requiring CHT to correct such failure; or (iii) becomes or is adjudicated insolvent or bankrupt, admits in writing its inability to pay its debts as they mature, or makes an assignment for the benefit of creditors; or CHT applies for or consents to the appointment of any receiver, trustee or similar officer for it or for all or any substantial part of its property; or such receiver, trustee or similar officer is appointed without the consent of CHT; or CHT institutes any bankruptcy, insolvency, reorganization, moratorium, arrangement, readjustment or debt, dissolution, liquidation or similar proceeding relating to it under the laws of any jurisdiction, or any such proceeding is instituted against CHT and is not dismissed within sixty (60) Business Days; or any judgment, writ, warrant or attachment or execution of similar process is issued or levied against a substantial part of CHT's property and remains unsatisfied for sixty (60) Business Days. (d) Waiver: The waiver by either Party of a breach or default of any provision of this Agreement by the other Party shall not be effective unless in writing and shall not be construed as a waiver of any succeeding breach of the same or of any other provision. Nor shall any delay or omission on the part of either Party to exercise or avail itself of any right, power or privilege by such Party shall constitute a waiver. (e) Effect of Termination: Upon the termination of this Agreement for any reason, subject to and without limiting the provisions of Section 12: (i) the Parties shall implement the Transition-Out Services pursuant to Section 10(f); (ii) at the end of the Transition-out Period (or earlier upon CHT's request) Ehave shall terminate and invalidate any Authentication IDs associated with CHT and any of its End Users; (iii) Ehave shall, but not earlier than twenty (20) Business Days after the later of termination or expiration of this Agreement or the Transition-out Period, destroy any copies of the End User Data contained in the Ehave Companion Solution and certify in writing to CHT that it has done so; (iv) CHT shall pay to Ehave the full amount of all Royalties payable hereunder as of the date of termination, if any, whether already invoiced or not (including any amounts due as late payment charges), and any other monies owing to Ehave hereunder; and (v) each Party will return to the other Party, or at the other Party's written request, destroy, in a secure manner all Confidential Information of the other Party which is then in its possession or control and certify in writing that it has done so. CHT acknowledges and agrees if any End User fails to download its End User Data from the Ehave Companion Solution in a timely manner (i.e. on or before the later of termination or expiry of this Agreement and the Transition-out Period), it may not have access to such information or such information may be destroyed by Ehave in accordance with the terms of this Section 10(e). Subject to Section 10(f), it is CHT's and each End User's responsibility to download and obtain all the End User Data on or prior to the termination of this Agreement or expiry of the Transition-out Period (whichever is later). Ehave shall have no responsibility for maintaining or providing to CHT or to any of its End Users the End User Data or any portion thereof, or any liability to CHT or any End User for destroying End User Data, in either case, from and after the twentieth (20th) Business Day after the termination or expiration of this Agreement or the Transition-out Period, whichever later.

16.

Source: EHAVE, INC., 20-F, 5/15/2019





(f) Transition Assistance: Without limiting the provisions of Section 11, commencing on the delivery of any notice of termination of this Agreement, and continuing through the effective date of termination and for a period of sixty (60) Business Days thereafter (the Transition-out Period), Ehave will, to the extent requested by CHT, provide to CHT (or at CHT's request to CHT's End User) such reasonable cooperation, assistance and services to facilitate the orderly wind down, transition and migration and transfer of the End User Data from Ehave to CHT (the Transition-out Services). (g) Survival of Covenants: Notwithstanding the termination or expiration of this Agreement for any reason, the covenants set out in this Section 10(g) and in Sections 7(c), 10(e), 10(f), 11, 12, 13, 14(c), 15, 16, 17, 19, 20(a) and those provisions set out in Section 1 as necessary to interpret the foregoing provisions, of this Agreement shall survive any such termination or expiration. 11. OWNERSHIP (a) Ehave's Ownership CHT acknowledges and agrees that, as between CHT and Ehave, Ehave owns all worldwide right, title and interest, including all Intellectual Property Rights, in and to the Ehave Companion Solution, including any developments, enhancements or customizations made as a result of Section 3 and any modifications, enhancements, upgrades, updates or Customization subsequent to the development and implementation in accordance with Section 3, excluding, however, any CHT Developments. CHT does not acquire any rights, title or ownership interests of any kind whatsoever, express or implied, in any of the foregoing other than the licenses granted herein. (b) CHT's Ownership Ehave acknowledges and agrees that, as between Ehave and CHT, CHT owns all worldwide right, title and interest, including all Intellectual Property Rights, in and to the CHT Developments. Ehave does not acquire any rights, title or ownership interests of any kind whatsoever, express or implied, in any of the foregoing other than the licenses granted herein. Further, as between CHT and Ehave, (i) CHT (or its End User) is and will remain the sole and exclusive owner of all right, title, and interest in and to End User Data, including all Intellectual Property Rights therein and/or relating thereto, subject only to the limited license granted in Section 5(c), and (ii) End User Data and CHT Developments are and will be the Confidential Information of CHT. CHT and End Users shall at all times, including in the event of termination of this Agreement and for a period thereafter as set out in Section 10(e), have access to their respective End User Data and the ability to download and/or export their End User Data out of the Ehave Companion Solution.

17.

Source: EHAVE, INC., 20-F, 5/15/2019





12. ESCROW (a) Escrow Agreement (i) Concurrently with execution of this Agreement or, at CHT's option, as soon as practicable after the Effective Date but in no event later than CHT's acceptance of and the launch of the Ehave Companion Solution, CHT and Ehave shall enter into a Source Code Escrow Agreement with a reputable software escrow agent mutually acceptable to the Parties (Escrow Agent), in or substantially in the form attached hereto as Schedule 7, or otherwise in a form acceptable to the Parties, acting reasonably, and to the Escrow Agent (the Escrow Agreement), providing for the release of the Source Code for the Software, as modified pursuant to Section 3 and all necessary programming documentation, utilities and tools used by Ehave to maintain the Software and to compile the source code into object code (excluding third party utilities and tools licensed by Ehave for which Ehave has not been granted the right to sublicense or otherwise make available such utilities and tools to third parties without additional charge, but including such information as necessary for CHT to obtain licenses to and obtain such third party utilities and tools), all in its then-existing form, to CHT, in the certain circumstances expressly stated in Section 12(b). The Escrow Agreement shall provide that the Software, including the Source Code and object code, Specifications and related documentation are and shall be deemed to be intellectual property and the rights under the Escrow Agreement and the license granted under Section 12(a)(iii) are deemed to be rights to use intellectual property for purposes of section 65.11(7) of the BIA and section 32(6) of the CCAA. (ii) Upon release of the Source Code by the Escrow Agent to CHT pursuant to the terms and conditions of the Escrow Agreement, Ehave hereby warrants that such Source Code and other materials are and will be the then current version of the Software as used by CHT in its provision to End Users of the eEhave Companion Solution under the Subscription Agreements and that Ehave shall throughout the Term keep the Source Code so deposited with the Escrow Agent current by periodically submitting material updates to the Escrow Agent from time to time, as necessary. Save and except for express warranties specified in this Agreement and the Escrow Agreement, Ehave specifically disclaims all other warranties, express or implied, including, without limitation, any warranty of merchantability and fitness for a particular purpose. (iii) In connection with the exercise of CHT's rights under the Escrow Agreement, Ehave hereby grants to CHT a non- exclusive, non-transferable (except as set forth in Section 20(f)), right and license to use and copy the materials deposited with the Escrow Agent, including the Source Code, its Specifications and documentation, and any resulting corrections, repairs, translations, enhancements, and other derivative works and improvements made by CHT, for the sole purposes of providing to CHT the ability to operate, support and maintain, the Ehave Companion Solution for its End Users from time to time, until such time that CHT is able to migrate off the Ehave Companion Solution, but in any event not exceeding twelve months from the date of release of the materials from escrow. CHT may use third parties to perform its foregoing rights, provided that any such third parties are not competitors of Ehave and shall be subject to confidentiality obligations. CHT expressly agrees, however, that CHT shall not exercise any of the foregoing right and license unless and until CHT obtains such Source Code from the Escrow Agent. CHT's obligations with respect to confidentiality and use of the Source Code shall be equivalent to CHT's obligations set forth in Section 13 of this Agreement. Notwithstanding any release of the Source Code pursuant to the provisions hereof, Ehave shall retain sole ownership of and other proprietary rights with respect to the Source Code (including any Source Code relating to any modifications made by CHT to the Source Code, all of which shall be owned by Ehave). CHT shall be responsible for all of the Escrow Agent's fees and charges under the Escrow Agreement.

18.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Release Conditions The parties acknowledge and agree that a Release Condition for purposes of the Escrow Agreement shall be deemed to mean any one or more of the following listed events (in addition to any other event specified as a release condition under the Escrow Agreement): (i) Ehave makes a general assignment for the benefit of creditors; (ii) Ehave voluntarily institutes any bankruptcy, insolvency, reorganization, moratorium, arrangement, readjustment or debt, dissolution, liquidation or similar proceeding relating to it under the laws of any jurisdiction, or any such proceeding is instituted against Ehave and is not dismissed within sixty (60) Business Days; or any judgment, writ, warrant or attachment or execution of similar process is issued or levied against a substantial part of Ehave's property and remains unsatisfied for sixty (60) Business Days; or Ehave applies for or consents to the appointment of any receiver, trustee or similar officer for it or for all or any substantial part of its property; or such receiver, trustee or similar officer is appointed without the consent of Ehave; (iii) Ehave consents to the filing of a petition of bankruptcy against it; (iv) a petition of bankruptcy is filed against Ehave which is not discharged within sixty (60) days; (v) Ehave becomes or is adjudicated by a court of competent jurisdiction as being bankrupt or insolvent or admits in writing its inability to pay its debts as they mature; Ehave ceases doing business as a going concern; (vi) Ehave undergoes a change of control or is a party to a merger or amalgamation; (vii) Ehave takes steps to dissolve, liquidate, wind up or otherwise terminate its existence; (viii) Ehave has terminated its provision of or ceased to provide the Ehave Companion Solution or support services for a continuing period of fifteen (15) Business Days or more, except pursuant to the termination of this Agreement by Ehave in accordance with its rights contained hrein. (c) Effect of Bankruptcy All of the Software, including the Source Code and object code, the Specifications and related documentation, and all other escrow deposit materials constitute intellectual property and all rights and licenses granted by Ehave to CHT under this Agreement or the Escrow Agreement (which is supplementary to this Agreement) are and shall be deemed to be licenses and rights to use intellectual property by CHT for the purposes of and as such terms are used and interpreted under section 65.11(7) of the BIA and section 32(6) of the CCAA. CHT shall have the right to exercise all rights and elections under the BIA and CCAA and all other applicable bankruptcy, insolvency and similar laws with respect to this Agreement, the Escrow Agreement and the subject matter hereof and thereof. Without limiting the generality of the foregoing, if Ehave or its estate becomes subject to any bankruptcy or similar proceeding subject to CHT's rights of election, all rights and licenses granted to CHT under this Agreement and the Escrow Agreement will continue subject to the respective terms and conditions hereof and thereof, and will not be affected, even by Ehave's rejection of this Agreement or the Escrow Agreement.

19.

Source: EHAVE, INC., 20-F, 5/15/2019





13. CONFIDENTIALITY (a) Obligation: Each Party acknowledges that all Confidential Information consists of confidential and proprietary information of the disclosing Party. Each Party shall, and shall cause its employees, agents and contractors to hold Confidential Information of the other Party in confidence, and shall use the same degree of care by instruction, agreement or otherwise, to maintain the confidentiality of the other Party's Confidential Information that it uses to maintain the confidentiality of its own Confidential Information, but with at least a reasonable degree of care commensurate with the nature and importance of such Confidential Information. Each Party agrees not to make use of Confidential Information other than for the exercise of rights or the performance of obligations under this Agreement (and the Source Code Escrow Agreement), and not to release, disclose, communicate it or make it available to any third person other than employees, agents and contractors of the Party who reasonably need to know it in connection with the exercise of rights or the performance of obligations by such Party under this Agreement (and the Source Code Escrow Agreement) and who are bound by confidentiality and restricted use obligations at least as protective of the Confidential Information as those set forth herein. Each Party agrees to notify the other Party in writing promptly of any loss or unauthorized disclosure or use of such other Party's Confidential Information and cooperate with such other Party to protect the confidentiality and ownership of all Intellectual Property Rights and other rights therein. (b) Subpoena: In the event that any Party receives a request to disclose all or any part of the Confidential Information of the other Party under the terms of a valid and effective subpoena or order issued by a court of competent jurisdiction or by a Governmental Authority, such Party agrees to (i) immediately notify the other Party of the existence, terms and circumstances surrounding such a request; (ii) consult with the other Party on the advisability of taking legally available steps to resist or narrow such request; and (iii) if disclosure of such Confidential Information is required, exercise its commercially reasonable efforts to obtain, and/or assist the other Party to obtain, at the other Party's expense, an order or other reliable assurance that confidential treatment will be accorded to such portion of the disclosed Confidential Information which the other Party so designates. (c) Injunctive Relief: Each Party acknowledges and agrees that any unauthorized use or disclosure by it of any of the other Party's Confidential Information, in whole or part, will cause irreparable damage to the disclosing Party, that monetary damages would be an inadequate remedy and that the amount of such damages would be extremely difficult to measure. The receiving Party agrees that the disclosing Party shall be entitled to seek temporary and permanent injunctive relief to restrain the receiving Party from any unauthorized disclosure or use. Nothing in this Agreement shall be construed as preventing the disclosing Party from pursuing any and all remedies available to it for a breach or threatened breach of a covenant made in this Section 13, including the recovery of monetary damages from the receiving Party.

20.

Source: EHAVE, INC., 20-F, 5/15/2019





14. REPRESENTATIONS, WARRANTIES AND DISCLAIMERS (a) Mutual Representations of the Parties: Each Party represents to the other that: (i) it is a company duly organized, validly existing and in good standing under the laws of its incorporation and it has full power and authority to enter into this Agreement and to perform each and every covenant and agreement herein contained; (ii) this Agreement has been duly authorized, executed and delivered by it and constitutes a valid, binding and legally enforceable agreement of it; (iii) the execution and delivery of this Agreement, and the performance of the covenants and agreements herein contained, are not, in any manner or to any extent, limited or restricted by, and are not in conflict with, any commercial arrangements, obligations, contract, agreement or instrument to which it is either bound or subject; and (iv) the execution and delivery of this Agreement and the performance of its covenants and agreements herein contained shall comply in all respects with all laws and regulations to which it or its business is subject. (b) Additional representations of Ehave: Ehave represents to CHT that Ehave possesses the knowledge, skill and experience necessary for the provision and completion of the Ehave Companion Solution in accordance with the terms of this Agreement. (c) Warranties Ehave warrants that for the duration of the Term, (i) the Ehave Companion Solution will substantially conform to and operate in accordance with, and have the functions and features set out in, the Specifications, and any related documentation provided by Ehave, and any such documentation shall be complete and accurate in all material respects; and the Ehave Companion Solution will not contain any material undocumented feature; (ii) Ehave has implemented and will maintain industry standard protection for the detection, protection and removal of Viruses; (iii) Ehave will perform all services under this Agreement in a timely, professional and workmanlike manner using personnel of required skill, experience and qualifications, and will devote adequate resources to meet its obligations (including the Service Level Commitments and its support obligations) hereunder; (iv) it has or will have all necessary right, power and authority, including all licenses and Intellectual Property Rights required, to provide and operate the Ehave Companion Solution and to grant all rights and licenses granted or required to be granted by it under this Agreement; and (v) Ehave is not aware of any infringement or misappropriation claims by any third party in relation to the Ehave Companion Solution.

21.

Source: EHAVE, INC., 20-F, 5/15/2019





(d) Exclusion of Other Warranties: Except as otherwise expressly stated in this Agreement, there are no express or implied warranties or conditions in relation to the Ehave Companion Solution that are the subject matter of this Agreement, including implied warranties or conditions of merchantable quality, fitness for a particular purpose, or non-infringement, or that the Ehave Companion Solution will meet CHT's or any End Users' needs or will be available for use at any particular time or will be error free. Under no circumstances will Ehave be liable for the results of CHT or any of its End Users' misuse of the Ehave Companion Solution, including any use contrary to Applicable Law. 15. INSURANCE (a) Required Insurance: Both Parties shall, at all times during the currency of this Agreement and for a period of one (1) year after the termination or expiration of this Agreement, maintain the following policies of insurance in effect: (i) a comprehensive general liability insurance policy, with minimum coverage of $1,000,000 per occurrence and in the annual aggregate for product liability and completed operations, covering bodily and personal injury, including death, and property damage, including loss of use; and (ii) an information and network technology blended liability insurance policy with an insured limit of at least $1,000,000 in the aggregate. (b) Evidence of Insurance: Upon the execution of this Agreement or at any time at a Party's request during the term of this Agreement, the other Party shall provide the requesting Party with evidence of the aforementioned insurance coverage in the form of a certificate of insurance acceptable to the requesting Party. In the event of any material change or cancellation of the required insurance policies, the applicable Party will provide the other Party with thirty (30) calendar days' prior written notice and will promptly replace such insurance policy in accordance with this Section 15, without lapse in coverage. 16. INDEMNITIES (a) Intellectual Property Indemnity Ehave shall defend at its own expense any claim, proceeding or suit (a Claim) brought against CHT and/or any of its directors, officers, employees, agents, subcontractors, affiliates and/or End Users (collectively, the CHT Indemnified Parties) to the extent such Claim alleges that the Ehave Companion Solution furnished hereunder or the use thereof by CHT or its End Users as authorized hereunder or in any Subscription Agreement infringes any copyright, Canadian patent, or registered trademark of a third person, and will indemnify and hold harmless the CHT Indemnified Parties from and against any and all related liabilities, costs, losses, damages and expenses (including reasonable legal fees) arising out of or in connection with or relating to any such Claim, provided that: (i) Ehave is given prompt written notice of the Claim or of any allegations or circumstances known to CHT which could reasonably result in a Claim; (ii) Ehave is given all reasonable information and assistance from CHT, at Ehave's expense, which Ehave may require to defend the Claim;

22.

Source: EHAVE, INC., 20-F, 5/15/2019





(iii) Ehave is given sole control of the defence of the Claim, and all negotiations for the settlement or compromise thereof, provided that Ehave shall promptly engage competent counsel and initiate defence in a professional manner and CHT may observe or participate in such proceedings with its own counsel at its own expense; and (iv) the alleged infringement does not result from any non-permitted uses, alterations, modifications or enhancements carried out by CHT, any End User or on its or their behalf by a third person (other than any Ehave personnel or contractors). If such Claim has occurred, or in Ehave's opinion is likely to occur, without limiting Ehave's obligation to defend and indemnify the CHT Indemnified Parties as aforesaid, Ehave may, at its option and expense, either procure for CHT the right to continue using the Ehave Companion Solution in accordance with this Agreement or modify or replace the same so that it becomes non-infringing without loss of functionality, or if none of the foregoing alternatives is reasonably available and at Ehave's discretion, discontinue the use of the Ehave Companion Solution on not less than sixty (60) Business Days' prior written notice to CHT and its End Users. The foregoing states the entire obligations of Ehave with respect to any infringement of Intellectual Property Rights of any third Person. (b) CHT' Indemnity CHT shall defend at its own expense any Claim brought against Ehave, its affiliates, directors, officers, employees and agents, to the extent such Claim: (i) alleges, directly or indirectly, that any End User Data infringes any Canadian copyright, patent or registered trademark of a third person; alleges, directly or indirectly, that the End User Data contains any Objectionable Content; (ii) arises through a breach by CHT of its obligations set out in Section 5(g); or (iii) is in relation to any of its End Users' use of the Ehave Companion Solution, including contrary to Applicable Law, except however to the extent as Ehave has indemnified CHT pursuant to Section 16(a); provided that CHT is given: (i) prompt written notice of the Claim or of any allegations or circumstances known to Ehave which could result in a Claim; (ii) all reasonable information and assistance from Ehave, at CHT's expense, which CHT may require to defend the Claim; and (iii) sole control of the defence of the Claim, and all negotiations for its settlement or compromise thereof. 17. LIMITATION OF LIABILITY (a) Consequential Damages Subject to Section 17(c), in no event shall either Party be liable to the other for any consequential, incidental, exemplary or punitive damages even if advised in advance of the possibility of such damages. Further, subject to Section 17(c), neither Party shall not be liable to the other Party for any lost revenue, lost profit or lost savings. (b) Limitation of Direct Damages Subject to Section 17(c), in no event shall either Party's liability under this Agreement exceed the aggregate of all amounts paid under this Agreement and amounts that have accrued but not yet been paid in the twelve (12) months preceding the event giving rise to the claim.

23.

Source: EHAVE, INC., 20-F, 5/15/2019





(c) Exceptions to Limitations Notwithstanding Sections 17(a) and 17(b), neither Party excludes or limits any liability for: (i) personal injury or death to the extent that such injury or death results from the negligence or wilful misconduct of a Party or its employees or subcontractors; (ii) fraud, fraudulent misrepresentation or fraudulent concealment; (iii) the Party's obligations set out in Sections 2(c), 5(b), 5(c), 6(b), 11, 13 or 16; (iv) CHT's payment obligations under Section 7; or (v) willful misconduct or gross negligence. (d) Application of Limitations and Exclusions The limitations and exclusions set out in this Section shall apply whether a claim, demand or action is based in contract, tort (including negligence), or otherwise. 18. FORCE MAJEURE Except for any obligation to make payments, any delay or failure of either Party to perform its obligations under this Agreement or under any Schedule attached hereto shall be excused if, and to the extent, that the delay or failure is caused by an event or occurrence beyond the reasonable control of the Party and without its fault or negligence and that could not have been prevented or avoided by the exercise of reasonable due diligence, such as, by way of example and not by way of limitation, acts of God, action by any Governmental Authority (whether valid or invalid), fires, flood, wind storms, explosions, riots, natural disasters, wars, terrorist acts, sabotage, labour problems (including lock-outs, strikes and slow downs, except for any labour problems of the Party claiming a force majeure event), or court order or injunction; provided that written notice of delay (including anticipated duration of the delay) shall be given by the affected Party to the other Party within two (2) Business Days of the affected Party first becoming aware of such event and the affected Party shall use diligent efforts to end the failure or delay and minimize the effects of such force majeure event. In the event that the force majeure event lasts for fifteen (15) Business Days or longer, either Party shall have the option to terminate this Agreement upon written notice to the other without liability. 19. DISPUTE RESOLUTION (a) Discussions: Each Party agrees to utilize all reasonable efforts to resolve any dispute, whether arising during the term of this Agreement or at any time after the expiration of termination of this Agreement, which touches upon the validity, construction, meaning, performance or effect of this Agreement or the rights and liabilities of the Parties or any matter arising out of or connected with this Agreement, promptly and in an amicable and good faith manner by negotiations between the Parties.

24.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Mediation: Either Party may submit a dispute to mediation by providing written notice to the other Party. In the mediation process, the Parties will try to resolve their differences voluntarily with the aid of a single, impartial mediator, who shall attempt to facilitate negotiations. The mediator shall be selected by agreement of the Parties. If the Parties cannot otherwise agree on a mediator within five (5) Business Days, a single mediator shall be designated by the ADR Institute of Canada, Inc. or any successor organization (ADR) at the request of a Party. Any mediator so designated must not have a conflict of interest with respect to any Party. The mediation shall be conducted as specified by the mediator and agreed upon by the Parties. The Parties agree to discuss their differences in good faith and to attempt, with the assistance of the mediator, to reach an amicable resolution of the dispute. The mediation shall be treated as a settlement discussion and therefore shall be confidential. The mediator may not testify for either Party in any later proceeding relating to the dispute. No recording or transcript shall be made of the mediation proceedings. Each Party shall bear its own costs and legal fees in the mediation. The Parties shall share the fees and expenses of the mediator equally. (c) Arbitration: Subject to Section 19(d), any dispute that has proceeded through mediation established in Section 19(b) without resolution may be submitted to arbitration. Any arbitration conducted pursuant to this Agreement shall take place in the City of Toronto, Ontario. The costs of the arbitration shall be borne equally by the Parties or as may be specified in the arbitrator's decision. The provisions of the Arbitration Act of Ontario, as amended, except as otherwise provided in this Agreement shall govern the arbitration process. The Parties agree to exclude the appeal provisions of the Arbitration Act, as may be amended from time to time, and in particular, section 45 thereof. The determination arising out of the arbitration process shall be final and binding upon the Parties to the arbitration. (d) Exceptions to Arbitration: The following matters shall be excluded from arbitration under this Agreement: (i) any disputes involving third Persons; (ii) breach of confidentiality by either Party; and (iii) intellectual property claims, whether initiated by third Persons or by one of the Parties to this Agreement. 20. MISCELLANEOUS (a) Notice: Every notice or other communication hereunder shall be deemed to have been duly given and made if in writing and if served by personal delivery upon the Party for whom it is intended, if delivered by registered or certified mail, return receipt requested, or by a national courier service, or if sent by fax (receipt of which is confirmed) to the Person at the address set forth below, or such other address as may be designated in writing hereafter, in the same manner, by such Person: To: Ehave To: CHT 277 Lakeshore Road E 1 Scarsdale Road Suite 203 Oakville, Ontario Toronto, Ontario Canada Canada L6J 6J3 M3B 2R2 Attention: Prateek Dwivedi, President & CEO Attention: Scott Woodrow, CEO Any such notification shall be deemed delivered (a) upon receipt, if delivered personally, (b) on the next Business Day, if sent by national courier service for next Business Day delivery or if sent by fax. Any correctly addressed notice or last known address of the other Party that is relied on herein that is refused, unclaimed, or undeliverable because of an act or omission of the Party to be notified as provided herein shall be deemed effective as of the first date that said notice was refused, unclaimed, or deemed undeliverable by the postal authorities by mail, through messenger or commercial express delivery services.

25.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Modifications: The Parties may modify this Agreement only upon written agreement. (c) Further Assurances: Each Party shall take such action (including, but not limited to, the execution, acknowledgement and delivery of documents) as may reasonably be requested by the other Party for the implementation or continuing performance of this Agreement. (d) Relationship: The Parties are independent contractors and no other relationship is intended. Nothing herein shall be deemed to constitute either Party as an agent, representative or employee of the other Party, or both Parties as joint venturers or partners for any purpose. Neither Party shall act in a manner that expresses or implies a relationship other than that of independent contractor. Each Party shall act solely as an independent contractor and shall not be responsible for the acts or omissions of the other Party. Neither Party will have the authority or right to represent nor obligate the other Party in any way except as expressly authorized by this Agreement. (e) Enurement: This Agreement shall enure to the benefit of and be binding upon each of the Parties hereto and their permitted successors and assigns. (f) No Assignment: Neither this Agreement nor any rights or obligations hereunder shall be assignable by a Party without the prior written consent of the other Party, provided that either Party shall have the right, on notice to but without the other Party's consent, to assign this Agreement and its rights and obligations contained herein, to an affiliate or to a third party who is not a competitor of the other Party in connection with a sale of all or substantially all of the assigning Party's business or assets relating to this Agreement. (g) Counterparts and Facsimile Execution and Delivery: This Agreement may be executed in counterparts, each of which shall be deemed to be an original and both of which together shall constitute one and the same instrument. To evidence its execution of an original counterpart of this Agreement, a Party may send a copy of its original signature on the execution page hereof to the other Party by facsimile transmission or email and such transmission shall constitute delivery of an executed copy of this Agreement to the receiving Party as of the date of receipt thereof by the receiving Party or such other date as may be specified by the sending Party as part of such transmission. (h) Language: It is the Parties desire and agreement that this Agreement and all Exhibits and associated documentation be drafted in English. Les Parties conviennent que la présente convention et tous les documents s'y rattachant, soient rédigés en anglais.

26.

Source: EHAVE, INC., 20-F, 5/15/2019





IN WITNESS WHEREOF, each Party hereto has caused this Agreement to be duly executed as of the date first written above by an officer authorized in that behalf. EHAVE, INC. COMPANION HEALTHCARE TECHNOLOGIES CORP per: /s/ Prateek Dwivedi per: /s/ Scott Woodrow Name: Prateek Dwivedi Name: Scott Woodrow Title: Chief Executive Officer Title: Chief Executive Officer

27.

Source: EHAVE, INC., 20-F, 5/15/2019

Highlight the parts (if any) of this contract related to Third Party Beneficiary that should be reviewed by a lawyer. Details: Is there a non-contracting party who is a beneficiary to some or all of the clauses in the contract and therefore can enforce its rights against a contracting party?