In this task, you're given a passage that represents a legal contract or clause between multiple parties, followed by a question that needs to be answered. Based on the paragraph, you must write unambiguous answers to the questions and your answer must refer a specific phrase from the paragraph. If multiple answers seem to exist, write the answer that is the most plausible.

Example Input: Exhibit 6.1

APPLICATION DEVELOPMENT AGREEMENT This Application Development Agreement (the Agreement) is entered into as of March 20, 2020, effective as of March 20, 2020 (the Effective Date) by and between InfinixSoft Global LLC, a Florida Limited Liability Company, with its principal office located at 360 NE 75 St Miami, Suite #127, 33138, Miami, Florida (the Developer) and Clickstream Corporation with its principal office located at 1801 Century Park East Suite 1201 Los Angeles, CA 90067 (the Client) and together with the Developer ( the Parties). RECITALS WHEREAS, the Client is engaged in the business of developing and designing mobile software applications; and WHEREAS, the Developer is engaged in the business of developing and designing application solutions; and WHEREAS, the Client wishes to engage the Developer as an independent contractor for the Client for the purpose of designing the Client's application (the Application) on the terms and conditions set forth below; and WHEREAS, the Developer wishes to design the Application and agrees to do so under the terms and conditions of this Agreement; and WHEREAS, each Party is duly authorized and capable of entering into this Agreement. NOW THEREFORE, in consideration of the above recitals and the mutual promises and benefits contained herein, the Parties hereby agree as follows: 1. PURPOSE. The Client hereby appoints and engages the Developer, and the Developer hereby accepts this appointment, to perform the services described in Exhibit A attached hereto and made a part hereof, in connection with the design of the Application (collectively, the Services). 2. COMPENSATION. The total compensation for the design of the app shall be as set forth in Exhibit A hereto. These payments shall be made in installments according to the schedule set forth in Exhibit A hereto. 3. TERM. This Agreement shall become effective as of the Effective Date and, unless otherwise terminated in accordance with the provisions of Section 4 of this Agreement, will continue until the expiration of the Warranty Period as defined in subsection 9(a) of this Agreement. 4. TERMINATION. (a) Types of Termination. This Agreement may be terminated: 1. By either Party on provision of seven (7) days written notice to the other Party in case of a Force Majeure Event. 2. Client has the unilateral right to cancel this agreement at any time within a 7-day notice period. Further, Developer can only cancel due to lack of payment. Client will have a 30 day right to cure before a cancelation can occur. 3. By either Party for a material breach of any provision of this Agreement by the other Party, if the other Party's material breach is not cured within three (3) days of receipt of written notice thereof. This shall include any delays to the timeline specified in Exhibit A. 4. By the Client at any time and without prior notice, if the Developer is convicted of any crime or offense, fails or refuses to comply with the written policies or reasonable directives of the Client, or is guilty of serious misconduct in connection with performance under this Agreement.

1 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





(b) Responsibilities after Termination. Following the termination of this Agreement for any reason, the Client shall promptly pay the Developer according to the terms of Exhibit A for Services rendered before the effective date of the termination (the Termination Date). The Developer acknowledges and agrees that no other compensation, of any nature or type, shall be payable hereunder following the termination of this Agreement. All intellectual property developed pursuant to this Agreement before the Termination Date shall be delivered to the Client within one day of the Termination Date. 5. RESPONSIBILITIES. (a) Of the Developer. The Developer agrees to do each of the following: 1. Create the Application System as detailed in Exhibit A to this Agreement and extend its best efforts to ensure that the design and functionality of the Application System meets the Client's specifications. 2. Devote as much productive time, energy, and ability to the performance of its duties hereunder as may be necessary to provide the required Services in a timely and productive manner and to the timeframe specified in this agreement. 3. Perform the Services in a workmanlike manner and with professional diligence and skill, as a fully trained, skilled, competent, and experienced personnel. 4. On completion of the Application System, assist the Client in installation of the Application System to its final location, which assistance will include helping the Client with its upload of the finished files to the Client's selected Web-hosting Client and submitting for approval on the Apple Store and Google Play Store. 5. Provide Services and an Application System that are satisfactory and acceptable to the Client and free of defects. 6. Communicate and show with the Client regarding progress it has made with respect to the milestones listed in this agreement. 7. Operate and Maintain the Application System through hosting of games including customer Support 8. Assist the Client in identification and acquisition of corporate sponsors 9. Include internal messaging system whereas users can communicate with each other (b) Of the Client. The Client agrees to do each of the following: 1. Engage the Developer as the creator of its Application System. 2. Provide all assistance and cooperation to the Developer in order to complete the Application System timely and efficiently. 3. Provide initial information and supply all content for the Application System. 4. Provide acceptance testing and certification within one week of deployment of final build

2 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





6. CONFIDENTIAL INFORMATION. The Developer agrees, during the Term and thereafter, to hold in strictest confidence, and not to use, except for the benefit of the Client, or to disclose to any person, firm, or corporation without the prior written authorization of the Client, any Confidential Information of the Client. Confidential Information means any of the Client's proprietary information, technical data, trade secrets, or know-how, including, but not limited to, business plans, research, product plans, products, services, customer lists, markets, software, developments, inventions, processes, formulas, technology, designs, drawings, engineering, hardware configuration information, marketing, finances, or other business information disclosed to the Developer by the Client either directly or indirectly. 7. PARTIES' REPRESENTATIONS AND WARRANTIES. (a) The Parties each represent and warrant as follows: 1. Each Party has full power, authority, and right to perform its obligations under the Agreement. 2. This Agreement is a legal, valid, and binding obligation of each Party, enforceable against it in accordance with its terms (except as may be limited by bankruptcy, insolvency, moratorium, or similar laws affecting creditors' rights generally and equitable remedies). 3. Entering into this Agreement will not violate the charter or bylaws of either Party or any material contract to which that Party is also a party. (b) The Developer hereby represents and warrants as follows: 1. The Developer has the right to control and direct the means, details, manner, and method by which the Services required by this Agreement will be performed. 2. The Developer has the experience and ability to perform the Services required by this Agreement. 3. The Developer has the right to perform the Services required by this Agreement at any place or location, and at such times as the Developer shall determine. 4. The Services shall be performed in accordance with and shall not violate any applicable laws, rules, or regulations, and the Developer shall obtain all permits or permissions required to comply with such laws, rules, or regulations. 5. The Services required by this Agreement shall be performed by the Developer, and the Client shall not be required to hire, supervise, or pay any assistants to help the Developer perform such services. 6. The Developer is responsible for paying all ordinary and necessary expenses of itself or its staff. 7. The Developer shall not develop, maintain or market a similar platform and will not compete with the Client directly or indirectly worldwide. 8. At the time cash online betting is implemented, incorporate and update the approximate 40 algorithms previously developed by Developer for Client. (c) The Client hereby represents and warrants as follows: 1. The Client will make timely payments of amounts earned by the Developer under this Agreement. 2. The Client shall notify the Developer of any changes to its procedures affecting the Developer's obligations under this Agreement at least three days prior to implementing such changes. 3. The Client shall provide such other assistance to the Developer as it deems reasonable and appropriate. 4. Because of the trade secret subject matter of Developer's business, Client agrees that, during the term of this Agreement and for a period of two (2) years thereafter, it will not solicit the services of any of Developer's employees, consultants or suppliers for Client's own benefit or for the benefit of any other person or entity.

3 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





8. APPLICATION REPRESENTATIONS AND WARRANTIES. (a) Performance. The Developer hereby warrants and represents that following delivery of the Application System to the Client (which shall be deeded to occur only on the date the Web Application is uploaded to the AWS for distribution) pursuant to Exhibit A (the Support Period), the Application will be free from programming errors and defects in workmanship and materials, and will conform to the specifications of Exhibit A. If programming errors or other defects are discovered during the Support Period, the Developer shall promptly remedy those errors or defects at its own expense. The developer will fix any bugs that may come up from the original contract after the 90 days warranty has passed. (b) No Disablement. The Developer hereby warrants and represents that the Application System, when delivered or accessed by the Client, will be free from material defects, and from viruses, logic locks, and other disabling devices or codes, and in particular will not contain any virus, Trojan horse, worm, drop-dead devices, trap doors, time bombs, or other software routines or other hardware component that could permit unauthorized access, disable, erase, or otherwise harm the Application System or any software, hardware, or data, cause the Application System or any software or hardware to perform any functions other than those specified in this Agreement, halt, disrupt, or degrade the operation of the Application System or any software or hardware, or perform any other such actions. 9. TIMING AND DELAYS. The Developer recognizes and agrees that failure to deliver the Application in accordance with the delivery schedule detailed in Exhibit A to this Agreement will result in expense and damage to the Client. The Developer shall inform the Client immediately of any anticipated delays in the delivery schedule and of any remedial actions being taken to ensure completion of the Application System according to such schedule. If a delivery date is missed, the Client may, in its sole discretion, declare such delay a material breach of the Agreement under subsection 4(a) and pursue all of its legal and equitable remedies. The Client may not declare a breach, and the Developer cannot be held in breach of this Agreement, of this section if such delay is caused by an action or failure of action of the Client. In such case, the Developer will provide the Client with written notice of the delay and work on the Application System will work until the reason for the delay has been resolved by the Client and written notice of that resolution has been provided to the Developer. 10. NATURE OF RELATIONSHIP. (a) Independent Contractor Status. The Developer agrees to perform the Services hereunder solely as an independent contractor. The Parties agree that nothing in this Agreement shall be construed as creating a joint venture, partnership, franchise, agency, employer/employee, or similar relationship between the Parties, or as authorizing either Party to act as the agent of the other. The Developer is and will remain an independent contractor in its relationship to the Client. The Client shall not be responsible for withholding taxes with respect to the Developer's compensation hereunder. The Developer shall have no claim against the Client hereunder or otherwise for vacation pay, sick leave, retirement benefits, social security, worker's compensation, health or disability benefits, unemployment insurance benefits, or employee benefits of any kind. Nothing in this Agreement shall create any obligation between either Party or a third party. (b) Indemnification of Client by Developer. The Client has entered into this Agreement in reliance on information provided by the Developer, including the Developer's express representation that it is an independent contractor and in compliance with all applicable laws related to work as an independent contractor. If any regulatory body or court of competent jurisdiction finds that the Developer is not an independent contractor and/or is not in compliance with applicable laws related to work as an independent contractor, based on the Developer's own actions, the Developer shall assume full responsibility and liability for all taxes, assessments, and penalties imposed against the Developer and/or the Client resulting from such contrary interpretation, including but not limited to taxes, assessments, and penalties that would have been deducted from the Developer's earnings had the Developer been on the Client's payroll and employed as an employee of the Client.

4 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





11. WORK FOR HIRE. (a) Work for Hire. The Developer expressly acknowledges and agrees that any all proprietary materials prepared by the Developer under this Agreement shall be considered works for hire and the exclusive property of the Client unless otherwise specified. These items shall include, but shall not be limited to, any and all deliverables resulting from the Developer's Services or contemplated by this Agreement, all tangible results and proceeds of the Services, works in progress, records, diagrams, notes, drawings, specifications, schematics, documents, designs, improvements, inventions, discoveries, developments, trademarks,, licenses, trade secrets, customer lists, databases, software, programs, middleware, applications, and solutions conceived, made, or discovered by the Developer, solely or in collaboration with others, during the Term of this Agreement relating in any manner to the Developer's Services. (b) Additional Action to Assign Interest. To the extent such work may not be deemed a work for hire under applicable law, the Developer hereby assigns to the Client all of its right, title, and interest in and to such work. The Developer shall execute and deliver to the Client any instruments of transfer and take such other action that the Client may reasonably request, including, without limitation, executing and filing, at the Client's expense, copyright applications, assignments, and other documents required for the protection of the Client's rights to such materials. (c) Notice of Incorporation of Existing Work. If the Developer intends to integrate or incorporate any work that it previously created into any work product to be created in furtherance of its performance of the Services, the Developer must obtain the Client's prior written approval of such integration or incorporation. If the Client, in its reasonable discretion, consents, the Client is hereby granted an exclusive, worldwide, royalty-free, perpetual, irrevocable license to use, distribute, modify, publish, and otherwise exploit the incorporated items in connection with the work product developed for the Client. 12. RETURN OF PROPERTY. Within three (3) days of the termination of this Agreement, whether by expiration or otherwise, the Developer agrees to return to the Client all Client products, samples, models, or other property and all documents, retaining no copies or notes, relating to the Client's business including, but not limited to, reports, abstracts, lists, correspondence, information, computer files, computer disks, and all other materials and all copies of such material obtained by the Developer during and in connection with its representation of the Client. All files, records, documents, blueprints, specifications, information, letters, notes, media lists, original artwork/creative, notebooks, and similar items relating to the Client's business, whether prepared by the Developer or otherwise coming into its possession, shall remain the Client's exclusive property. 13. INDEMNIFICATION. (a) Of Client by Developer. The Developer shall indemnify and hold harmless the Client and its officers, members, managers, employees, agents, contractors, sub licensees, affiliates, subsidiaries, successors and assigns from and against any and all damages, liabilities, costs, expenses, claims, and/or judgments, including, without limitation, reasonable attorneys' fees and disbursements (collectively, the Claims) that any of them may suffer from or incur and that arise or result primarily from (i) any gross negligence or willful misconduct of the Developer arising from or connected with the Developer's carrying out of its duties under this Agreement, or (ii) the Developer's breach of any of its obligations, agreements, or duties under this Agreement. (b) Of Developer by Client. The Client shall indemnify and hold harmless the Developer from and against all Claims that it may suffer from or incur and that arise or result primarily from (i) the Client's operation of its business, (ii) the Client's breach or alleged breach of, or its failure or alleged failure to perform under, any agreement to which it is a party, or (iii) the Client's breach of any of its obligations, agreements, or duties under this Agreement; provided, however, none of the foregoing result from or arise out of the actions or inactions of the Developer.

5 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





14. INTELLECTUAL PROPERTY. (a) No Intellectual Property Infringement by Developer. The Developer hereby represents and warrants that the use and proposed use of the Application by the Client or any third party does not and shall not infringe, and the Developer has not received any notice, complaint, threat, or claim alleging infringement of, any trademark, copyright, patent, trade secrets, industrial design, or other rights of any third party in the Application, and the use of the Application will not include any activity that may constitute passing off. To the extent the Application infringes on the rights of any such third party, the Developer shall obtain a license or consent from such third party permitting the use of the Application. It is hereby stated, the Application developed under this agreement is the exclusive worldwide sole property of Client. (b) No Intellectual Property Infringement by Client. The Client represents to the Developer and unconditionally guarantees that any elements of text, graphics, photos, designs, trademarks, or other artwork furnished to the Developer for inclusion in the Application are owned by the Client, or that the Client has permission from the rightful owner to use each of these elements, and will hold harmless, protect, indemnify, and defend the Developer and its subcontractors from any liability (including attorneys' fees and court costs), including any claim or suit, threatened or actual, arising from the use of such elements furnished by the Client. (c) Continuing Ownership of Existing Trademarks, Copyrights and Patents. The Developer recognizes the Client's right, title, and interest in and to all service marks, trademarks, trade names , Copyrights and Patents used by the Client and agrees not to engage in any activities or commit any acts, directly or indirectly, that may contest, dispute, or otherwise impair the Client's right, title, and interest therein, nor shall the Developer cause diminishment of value of said trademarks or trade names through any act or representation. The Developer shall not apply for, acquire, or claim any right, title, or interest in or to any such service marks, trademarks, trade names, Copyrights and Patents or others that may be confusingly similar to any of them, through advertising or otherwise. Effective as of the termination of this Agreement, the Developer shall cease to use all of the Client's trademarks, marks, and trade names. (d) The Developer recognizes that the complete Intellectual Property of the project belongs to the Client. The Developer will deliver to the Client all the source code, licenses and other assets used during the process as soon as the work described in this proposal is finished under client acceptation and after receiving the last payment. 15. AMENDMENTS. No amendment, change, or modification of this Agreement shall be valid unless in writing and signed by both Parties. 16. ASSIGNMENT. The Client may assign this Agreement freely, in whole or in part. The Developer may not, without the written consent of the Client, assign, subcontract, or delegate its obligations under this Agreement, except that the Developer may transfer the right to receive any amounts that may be payable to it for its Services under this Agreement, which transfer will be effective only after receipt by the Client of written notice of such assignment or transfer. 17. SUCCESSORS AND ASSIGNS. All references in this Agreement to the Parties shall be deemed to include, as applicable, a reference to their respective successors and assigns. The provisions of this Agreement shall be binding on and shall inure to the benefit of the successors and assigns of the Parties. 18. FORCE MAJEURE. A Party shall be not be considered in breach of or in default under this Agreement on account of, and shall not be liable to the other Party for, any delay or failure to perform its obligations hereunder by reason of fire, earthquake, flood, explosion, strike, riot, war, terrorism, or similar event beyond that Party's reasonable control (each a Force Majeure Event); provided, however, if a Force Majeure Event occurs, the affected Party shall, as soon as practicable:

6 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





(a) notify the other Party of the Force Majeure Event and its impact on performance under this Agreement; and (b) use reasonable efforts to resolve any issues resulting from the Force Majeure Event and perform its obligations hereunder. 19. NO IMPLIED WAIVER. The failure of either Party to insist on strict performance of any covenant or obligation under this Agreement, regardless of the length of time for which such failure continues, shall not be deemed a waiver of such Party's right to demand strict compliance in the future. No consent or waiver, express or implied, to or of any breach or default in the performance of any obligation under this Agreement shall constitute a consent or waiver to or of any other breach or default in the performance of the same or any other obligation. 20. NOTICE. Any notice or other communication provided for herein or given hereunder to a Party hereto shall be in writing and shall be given in person, by overnight courier, or by mail (registered or certified mail, postage prepaid, return-receipt requested) to the respective Parties as follows: If to the Client: Contact: Frank Magliochetti, CEO Company Name: Clickstream Corp. Main Address: 1801 Century Park East Suite 1201 Los Angeles, CA 90067 If to the Developer: Contact: Ivan Saroka, CEO Company Name: InfinixSoft Global LLC Main Address: 360 NE 75th St. Suite #127, 33138, Miami, Florida 21. GOVERNING LAW. This Agreement shall be governed by the laws of the state of Florida. If litigation results from or arises out of this Agreement or the performance thereof, each Party shall be responsible for its own attorneys' fees, court costs, and all other expenses, whether or not taxable by the court as costs. 22. COUNTERPARTS/ELECTRONIC SIGNATURES. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original but all of which shall constitute one and the same instrument. For purposes of this Agreement, use of a facsimile, e-mail, or other electronic medium shall have the same force and effect as an original signature. 23. SEVERABILITY. Whenever possible, each provision of this Agreement will be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Agreement is held to be invalid, illegal, or unenforceable in any respect under any applicable law or rule in any jurisdiction, such invalidity, illegality, or unenforceability will not affect any other provision or any other jurisdiction, but this Agreement will be reformed, construed, and enforced in such jurisdiction as if such invalid, illegal, or unenforceable provisions had never been contained herein. 24. ENTIRE AGREEMENT. This Agreement constitutes the final, complete, and exclusive statement of the agreement of the Parties with respect to the subject matter hereof and supersedes any and all other prior and contemporaneous agreements and understandings, both written and oral, between the Parties.

7 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





25. HEADINGS. Headings used in this Agreement are provided for convenience only and shall not be used to construe meaning or intent. ********************************************************************************************** EXHIBIT A A. PURPOSE OF APPLICATION SYSTEM. To create a new iOS / Android Native app and a web responsive site to allow users to connect with each other inside a unique social betting platform. The Platform is social trivia, initially sports trivia and other trivia contests leading to peer to peer betting intended for the causal and non- professional betting market. A landing page to promote the product is included as well for desktop and mobile devices. Developer will publish the app in Apple Store / Google Play Store with developer accounts registered to the client. The responsive website will be uploaded and deployed into an AWS Environment also registered to the client. The applications and responsive website will be fed by a Ruby on Rails backend with the according API. The API will be open to be used in other sports betting platforms. The app will be developed under the following considerations: ● Native iOS Swift 5.0 Language with Xcode Development Environment. ● Native JAVA with Android Studio for Android Devices with OS 6.0+ ● Ruby On Rails Backend + PostgreSQL + Rest API ● HTML5 + CSS 3 + Bootstrap Core Platform The Core of Click Stream is a free to play gaming platform that caters untapped market of the causal users that will spend a few seconds to interact with a platform for free in order to win real money. Our primary target is not the sports betters or the fantasy players. We target a more general demographic that is much more general and includes more of the female population. Our games will initially be quick to play quiz type games that allows the user to get involved in around 20 seconds, and then receive results from push notifications. Game types are set up dynamically with live game shows with Hosts 2 - 4 times per month. Because the format doesn't change, we can run games nightly for NBA to NHL, NFL to individual events such as the Oscars, other awards shows, and new sporting events such as Soccer and Nascar. Games and events automated from the backend and launched automatically. Api's Are plugged in to track results in real time, and there is a manual option to allow customs events that can be run through the platform. Business model- What sets our platform apart from other platforms in this untapped casual industry is that we have winners win significant amounts of money via time breakers, timing of inputting answers etc. Competitor platforms pay out an average of a few dollars. Our winners are more top loaded and pay out around $2,500 per the top 5 and $1,000 per the top 10. Initially monetization is based upon sponsors paying out the pots. IE, a pot for a single game will be around $25,000 to the winners and Sponsors will pay around $30,000 to $35,000 to sponsor the event. In return they will get around 30,000-75,000 unique user hits and eyeballs to their product/company.

8 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





Eventually the platform will expand into affiliate sales of products and once the audience has grown large enough, peer to peer betting. Monetization We will initially fund the first month of pots in order to attract enough users to get sponsors. After the first month we will have enough users to begin having sponsors pay the pots. We will then expand to peer to peer betting and advertising. B. SERVICES. The Developer will develop the mobile application based on the Client's specifications, will assist the Client in acquiring corporate sponsors and will operate and maintain the Application System through hosting of games including customer support. The Client will provide The Developer with all necessary information to carry out the development process. C. SPECIFICATIONS. Features for Website & iOS / Android Mobile App for users include: ● Home Screen ● Users Sign in / Sign up ● Profile Creation / Edition with ● Social Networks links ● Add image / Videos ● In App Purchase by each platform convenient method + Stripe.com integration on website. ● Lineup Creation ● SMS/email alert system (when a lineup has to be changed). ● Monetization / Subscription Model ● Mirco social betting ● Peer to Peer betting ● Group betting ● Dynamic Quiz game Engine ● Other dynamic Game Engines ● Homepage with newsfeed, how to play screens, institutional information, Twitter feeds, promotions and other CTAs. ● Historical data with How your lineup did compared to winning lineups. ● Push Notification ● Pop up (Advertiser) ● Rate Us ● Chat ● Block / Delete ● Terms of Use / Privacy Policy ● Analytics integration Web Admin Dashboard features include: ● Statistics to see the data in real-time ● Resolve payment issues ● Users Main Administration ● Disable / Lock Users ● Homepage features administration. ● Confirm Signup ● Forgot Password ● Payment success / receipt ● Payment Failed ● Renew Reminder ● Renew Notice

9 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





Transactional emails ● Welcome Email ● Order Confirmation ● Forgot Password Notes ● UI / UX design is included in the proposal. ● The source code belongs to the client and will be delivered as soon as the project is fully finished. ● Confidentiality: The main concept and idea of the platform are not to be shared by Developer. D. COMPLETION SCHEDULE. The schedule for completion of the Application Development (the Schedule) and the responsibilities under the Agreement is detailed as follows: Mobile / Web App development: 24 weeks + 4 weeks for QA & Details. E. MAINTENANCE AND SUPPORT. The Maintenance & Support is not included in this contract, but we suggest making a plan in the future that includes bug fixing, server monitoring and constant optimization of the apps. 90 days warranty (bugfixing) support is included. F. MILESTONES. ● Week 1 -> UI Design + Logo + Look & Feel ● Week 2-> UI Design - 40% of the UX flow completed ● Week 4 -> UI Design - 75% of the UX flow completed ● Week 6 -> Finished UI Design + Feedback / Technical Documentation ● Week 8 -> Final UI Design - Initial Dev. Process - Backend Development Started ● Week 10 -> Initial Dev. builds with 3 or more screens (hardcoded frontend) for iOS ● Week 12 -> Second Dev. builds with 6 or more screens (hardcoded frontend) for iOS ● Week 14 -> Third Dev. builds with all screens (hardcoded frontend) for iOS / Backend CMS in alpha stage ● Week 16 -> Registration process and Home APIs Integrated in Dev. builds. ● Week 18 ->Other APIs Integrated in Dev. builds. ● Week 20 -> Mobile Apps in Alpha Stage with 70% of the APIs Integrated ● Week 22 -> Mobile Apps in Alpha Stage with 90% of the APIs Integrated ● Week 23 -> Mobile Apps in Beta Stage of the APIs Integrated + Payment Gateway Integration ● Week 24 -> Final RC1 Build uploaded to stores + AWS Production Deployment subject to acceptance testing by client G. PAYMENT SCHEDULE. The total cost for the development of the project is $ 480,000. - Developer has accepted 4,122,394 shares of Clients common stock in exchange for $180,000 worth of services to be provided. The Shares were paid to INFX Development, LLC. (Certificate # 1054) and accepted by Developer as payment on December 30t h, 2019 Client will form subsidiary and register the new business if necessary.

10 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





The Client agrees to pay to the Developer for the development of the project as listed above, the amount of the other $300,000. - according to the following schedule: ● $30,000. - down payment. ● $30,000.- mid payment (Week 2). ● $30,000.- mid payment (Week 6). ● $30,000.- mid payment (Week 9). ● $30,000.- mid payment Week 12). ● $30,000.- mid payment (Week 16). ● $30,000.- mid payment (Week 20). ● $90,000.- following Client acceptance of the Application, and when RC1 version is delivered and uploaded to stores. By signing below, the Parties agree to comply with all of the requirements contained in this agreement. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first above written Clickstream Corp. By: Frank Magliochetti, CLIENT CEO Name: Title: CEO InfinixSoft Global LLC DEVELOPER By: Name: Ivan Alejandro Saroka Title: CEO - Founding Partner 11 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020 
Question: Highlight the parts (if any) of this contract related to Covenant Not To Sue that should be reviewed by a lawyer. Details: Is a party restricted from contesting the validity of the counterparty’s ownership of intellectual property or otherwise bringing a claim against the counterparty for matters unrelated to the contract?
Example Output: The Developer recognizes the Client's right, title, and interest in and to all service marks, trademarks, trade names , Copyrights and Patents used by the Client and agrees not to engage in any activities or commit any acts, directly or indirectly, that may contest, dispute, or otherwise impair the Client's right, title, and interest therein, nor shall the Developer cause diminishment of value of said trademarks or trade names through any act or representation

Example Input: [Confidential Treatment Requested]

                     Exhibit 10.11

CO-BRANDING AGREEMENT

This Co-Branding Agreement (this Agreement) dated March 3, 2000 (the Effective Date) is entered into between VerticalNet, Inc., a Pennsylvania corporation having a principal place of business at 700 Dresher Road, Suite 100, Horsham, Pennsylvania, 19044 (VerticalNet), and Impresse Corporation, a California Corporation, having a principal place of business at 1309 South Mary Avenue, Sunnyvale, California, 94087 (Impresse).

BACKGROUND

WHEREAS, VerticalNet owns and operates a series of Online Communities (defined below) that are accessible via the World Wide Web, each of which is designed to be an online gathering place for businesses of a certain type or within a certain industry; and

WHEREAS, Impresse desires to provide its commercial printing services (the Impresse Services) to Users (defined below) of VerticalNet Sites (defined below); and

WHEREAS, Impresse and VerticalNet desire to create Co-Branded Site (defined below) where users will be able to register to review and utilize the Impresse Services and to promote such Co-Branded Site on VerticalNet Sites.

NOW, THEREFORE, in consideration of the mutual covenants herein, and intending to be legally bound hereby, VerticalNet and Impresse agree as follows:

1.  DEFINITIONS

1.1. AFFILIATE shall mean, when used with reference to a party, any individual or entity directly or indirectly controlling, controlled by or under common control with such party. For purposes of this definition, control means the direct or indirect ownership of at least 50% of the outstanding voting securities of a party, or the right to control the policy decisions of such party.

1.2. BANNER shall mean a graphical image advertising the Impresse Site that is posted in an area reasonably designated by VerticalNet for similar banner advertisements and shall contain a Link (defined below) to the Co-Branded Site.

1.3. CO-BRANDED CONTENT shall mean all materials, data and similar information presented on the pages of the Co-Branded Site.

1.4. CO-BRANDED SITE shall mean the Site (defined below) that contains both a Frame (defined below) and a Window (defined below) which includes the Impresse Area (defined below) and the VerticalNet Area (defined below) of the Co-Branded Site.

1.5. CONFIDENTIAL INFORMATION shall mean, subject to the provisions of Section 7.2  [EXCLUSIONS], all proprietary and confidential information of a party, including, without limitation, trade secrets, technical information, business information, sales information, customer and potential customer lists and identities, product sales plans, sublicense agreements, inventions, developments, discoveries, software, know-how, methods, techniques, formulae, data, processes and other trade secrets and proprietary ideas, whether or not protectable under patent, trademark, copyright or other areas of law, that the other party has access to or receives. For purposes of this Agreement,

1

* Represents confidential information for which Impresse Corporation is seeking confidential treatment with the Securities and Exchange Commission.

the Co-Branded Content shall not be considered Confidential Information of Impresse. For purposes of this Agreement, this Agreement shall be considered Confidential Information.

1.6. E-COMMERCE CENTER shall mean a web page on a VerticalNet Site which is customized by VerticalNet to include a vendor's information, including the vendor's branding; a Link to the vendor's catalog, auction item listings; the vendor's career center including employment information; archives of; and Links to other related content locations.

1.7. FRAME shall mean a portion of a Web page which surrounds a Window on the top and left.

1.8. IMPRESSE AREA shall mean the Window portion of the Impresse Site (defined below) less the Frame that will be placed around the Window of the Co-Branded Site.

1.9. IMPRESSE MARK shall mean any trademark, service mark, trade name, domain name, design or logo of Impresse or its Affiliates.

1.10. IMPRESSE SITE shall mean the Site located at www.impresse.com (and any successor Site thereto).

1.11. IMPRESSE-VERTICALNET REVENUE shall have the meaning defined in Section 4.6.2  [REVENUE SHARING].

1.12. INTELLECTUAL PROPERTY shall mean any and all trade secrets, patents, copyrights, trademarks, service marks, URLs, trade dress, brand features, know-how and similar rights of any type under the laws of any applicable governmental authority, including, without limitation, all applications and registrations relating to any of the foregoing.

1.13. INTELLECTUAL PROPERTY RIGHTS shall mean all rights in and to Intellectual Property, including, without limitation, all patent rights, copyrights, trademarks, service marks, know-how and trade secrets.

1.14. LAUNCH DATE shall mean the day on which the Co-Branded Site and the V-Solutions Area become fully operational and generally available on the Internet.

1.15. LINK shall mean a link, including but not limited to a hyperlink,

Source: IMPRESSE CORP, S-1/A, 3/22/2000





button or banner, that connects two Sites in a manner so that when a User clicks on the link, the User is transferred directly from one Site to a second Site.

1.16. NEWSLETTER shall mean a text message containing information supplied by Impresse and approved by VerticalNet (which approval shall not be unreasonably withheld) that is transmitted via e-mail to Users of the VerticalNet Sites who have provided their e-mail addresses to VerticalNet along with permission to transmit such messages to the e-mail address.

1.17. ONLINE COMMUNITY shall mean a VerticalNet Site that acts as a comprehensive source of information, dialogue and commerce for and links to E-Commerce Centers and other Sites for a particular industry or service market.

2

1.18. PROPRIETARY FEATURE shall mean any name, trademark, service mark, trade name, domain name, navigational element, copyright, or logo which is proprietary to Impresse and/or VerticalNet, as appropriate.

1.19. SITE shall mean a site located on the World Wide Web portion of the Internet.

1.20. TERM shall have the meaning set forth in Section 5.1  [TERMINATION AND RENEWAL]

1.21. URL shall mean a universal resource locator used for the purpose of identifying a Site located on the Internet.

1.22. USER shall mean a single person who accesses and views a Site whether directly from a web browser or through a Link.

1.23. USER DATA shall mean all data generated by an Internet server that relates to file requests, user identification, transaction logs, session times and other information regarding the Users generated or collected by or through a Co-Branded Site, but excluding any information that relates or refers to a particular project of such User.

1.24. V-SOLUTIONS AREA shall mean a hub page accessible via a Link from the home page of each VerticalNet Site which shall contain a list of categories of business services, with each category further listing entities that provide such services. Each individual company listing shall contain a Link to a Web page hosted by VerticalNet that describes such company and the services it offers. The V-Solutions Area will also feature the V-Solutions Link (defined below).

1.25. V-SOLUTIONS LINK shall mean the Link from the V-Solutions Area to the Co-Branded Site.

1.26. VERTICALNET AREA shall mean the Frame area of the Co-Branded Site.

1.27. VERTICALNET MARK shall mean any trademark, service mark, trade name, domain name, design or logo of VerticalNet.

1.28. VERTICALNET-IMPRESSE USERS shall have the meaning defined in Section 4.6.1  [VerticalNet Impresse Users]

1.29. VERTICALNET SITE shall mean a Site owned and operated by VerticalNet in the United States or a portion of such Site designated by VerticalNet.

1.30. WINDOW shall mean a portion of a Web page that is surrounded by a Frame.

1.31. YEAR 2000 COMPLIANT shall mean with respect to any computer software that to the extent that such software contains date-dependent functionality, will: (1) contain four digit year codes, (2) properly process dates and date values before, through and beyond January 1, 2000, including date calculations with dates both before and after January 1, 2000, and (3) not suffer any impact on performance as a result of dates beyond January 1, 2000; provided, however, that for this warranty to apply the operating systems on which such software is being run, and any network servers, Web browsers, databases and other software that is used in conjunction with such software must also be Year 2000 Compliant as defined herein.

3

2.   CO-BRANDED SITE

2.1. Impresse shall be responsible for: (a) the design, layout, development, hosting and maintenance of the Impresse Area of the Co-Branded Site; (b) providing VerticalNet with reasonable instructions and information regarding the Impresse Services; (c) providing a tabbed area prominently featured in a user interface within the Impresse Area of the Co-Branded Site that points to a VerticalNet Online Community or Online Communities; (d) modifying the Impresse online registration forms and system available on the Co-Branded Site to require Impresse users to identify and match their business activities with a VerticalNet Online Community or Online Communities; and (e) providing VerticalNet with the URL addresses for the Co-Branded Site.

2.2. VerticalNet shall be responsible for: (a) the design, layout, development, hosting and maintenance of the VerticalNet Area of the Co-Branded Site; and (b) the design, layout, development, hosting and maintenance of the V-Solutions Link.

2.3. Beginning on the Launch Date and continuing during the Term, VerticalNet shall display the V-Solutions Area on the VerticalNet Sites. VerticalNet shall likewise, during the Term, implement and maintain the V-Solutions Link.

2.4. Beginning on the Launch Date and continuing during the Term, VerticalNet shall not place advertising relating to the commercial printing entities listed on Exhibit A, or other such entities subsequently identified by Impresse, on the VerticalNet Area of the Co-Branded Site.

2.5. Impresse hereby grants to VerticalNet a non-exclusive, non-transferable, royalty-free, right and license to link to the Impresse Area of the Co-Branded Site. Impresse shall permit Users who access the Co-Branded Site to access and use Co-Branded Content from the Co-Branded Site for the personal use of such Users in accordance with the then-current terms of Impresse's standard license agreement governing the use of such Co-Branded Content.

Source: IMPRESSE CORP, S-1/A, 3/22/2000





2.6. Nothing in this Agreement shall be construed as preventing Impresse or VerticalNet from developing other co-branded versions of their materials, data, information and content.

3.   ONGOING SUPPORT

3.1. Impresse shall use commercially reasonable efforts to respond to all support requests by VerticalNet relating to the Co-Branded Site within one Business Day (as defined below) of Impresse's receipt of such notification. Impresse shall use reasonable efforts to cure the reported problem as soon as reasonably possible. VerticalNet shall provide Impresse with all information reasonably requested by Impresse in connection with a reported problem for which VerticalNet is requesting support under this Section 3.1  [ONGOING SUPPORT]. VerticalNet shall use commercially reasonable efforts to respond to all support requests by Impresse relating to the Co-Branded Site within one Business Day (as defined below) of VerticalNet's receipt of such notification. VerticalNet shall use reasonable efforts to cure the reported problem as soon as reasonably possible. Impresse shall provide VerticalNet with all information reasonably requested by VerticalNet in connection with a reported problem for which Impresse is requesting support under this Section 3.1  [ONGOING SUPPORT].

4

[Confidential Treatment Requested]

3.2. Impresse will identify to VerticalNet primary and secondary contacts who will be familiar with the Co-Branded Site and this Agreement. VerticalNet will identify to Impresse primary and secondary contacts who will be familiar with the Co-Branded Site and this Agreement.

3.3. VerticalNet shall have access to technical support from Impresse by telephone from 8 a.m. Pacific Standard Time to 5 p.m. Pacific Standard Time, Monday through Friday, Impresse holidays excluded (each a Business Day, collectively Business Days). Impresse shall have access to technical support from VerticalNet by telephone from 6 a.m. Eastern Standard Time to 6 p.m. Eastern Standard Time, Monday through Friday, VerticalNet holidays excluded.

4.   THE COMMERCIAL TERMS

4.1. DEVELOPMENT FEES. For the design, development and integration of the V-Solutions Area and the VerticalNet Area of the Co-Branded Site, Impresse shall pay to VerticalNet a one-time, nonrefundable development fee in the amount of [*] payable on the Effective Date.

4.2. SLOTTING FEES. For the display of the V-Solutions Area and the V-Solutions Link, Impresse shall pay to VerticalNet a slotting fee in the amount of [*] payable pursuant to the terms of Section 4.5  [PAYMENT TERMS].

4.3. BANNER/NEWSLETTER PURCHASE COMMITMENT. During the Term of this Agreement, Impresse agrees to purchase from VerticalNet Banners and Newsletters for a total price of at least $[*] as set forth below in this Section 4.3  [BANNER/NEWSLETTER PURCHASE COMMITMENT]. All prices for such Banners and Newsletters shall be offered to Impresse at a [*]% discount off of VerticalNet's then current prices for similar Banners or Newsletters. All purchases shall be subject to VerticalNet's standard terms and conditions governing advertising on VerticalNet Sites. Impresse agrees to purchase at least $[*] of such Banners and Newsletters in each calendar quarter after the Effective Date until a total of $[*] have been purchased, provided, the total dollar amount purchased by Impresse in any calendar quarter shall not consist of greater than 70% of either Banners or Newsletters. Payment of the fees set forth in this Section shall be made pursuant to the terms of Section 4.5  [PAYMENT TERMS].

4.4. HOSTING FEE. Impresse shall pay VerticalNet a service fee of $[*] for the hosting and maintenance of the Co-Branded Site and the V-Solutions Link, payable pursuant to the terms of Section 4.5  [PAYMENT TERMS].

4.5. PAYMENT TERMS. Impresse shall pay the fees set forth in Sections 4.2  [SLOTTING FEES], 4.3  [BANNER/NEWSLETTER PURCHASE COMMITMENT] and 4.4  [HOSTING FEE] as an aggregate, totaling $[*] payable in four equal quarterly installments of $[*] beginning on May 31, 2000 and thereafter on August 31, 2000 November 30, 2000 and February 28, 2001, respectively.

4.6. REVENUE SHARING. Impresse shall pay VerticalNet [*]of Impresse VerticalNet Revenue accruing during the term of this Agreement, payable to VerticalNet on or before the thirtieth day of the calendar quarter immediately following the quarter in which such revenue was collected by Impresse. Such payments shall be accompanied by a statement containing reasonable detail of the type and number of transactions from which the Impresse

5

* Represents confidential information for which Impresse Corporation is seeking confidential treatment with the Securities and Exchange Commission.

VerticalNet Revenue was derived, the total Impresse VerticalNet Revenue for such period and the total fees payable to VerticalNet pursuant to this Section 4.6  [REVENUE SHARING].

4.6.1. VerticalNet Impresse Users are the Users that register with Impresse through the Co-Branded Site, but specifically excluding those Users who have previously registered with Impresse other than through the Co-Branded Site.

4.6.2. The Impresse VerticalNet Revenue is Impresse's total net transaction and subscription revenues collected by Impresse during the term of this Agreement from VerticalNet Impresse Users.

4.6.3. If government regulations prevent Impresse from sharing any revenues associated with Impresse Services, VerticalNet and Impresse shall negotiate in good faith a compensation structure that seeks to provide VerticalNet with compensation equal to that set forth in Section 4.6  [REVENUE SHARING].

4.7. TAXES. All payments required under this Agreement are exclusive of federal, state, local and foreign taxes, duties, tariffs, levies and similar assessments. When applicable, such taxes shall appear as separate items on a party's invoice or statement to the other party. Payment of such taxes or charges shall be the responsibility of the party whose obligation it is under this Agreement to make the payment in respect of which such taxes are assessed, excluding any taxes based upon the other party's net income. In lieu thereof, a party shall provide the other party with a tax or levy exemption certificate acceptable to the taxing or levying authority.

Source: IMPRESSE CORP, S-1/A, 3/22/2000





4.8. AUDITS. During the term of this Agreement and for one year thereafter, VerticalNet shall have the right to appoint a certified public accountant to audit Impresse's financial records relating to such payment to verify the accuracy of Impresse's financial records in order to verify the amount of the payments owed and/or paid hereunder, but no more frequently than once per year. If the amount owed by Impresse to VerticalNet was underpaid, the additional amount owed shall be paid to VerticalNet within 15 days of notice of such underpayment to Impresse. If the amount owed by Impresse to VerticalNet was underpaid in excess of 10% of the amount owed, the fees of such audit shall also be paid to VerticalNet within 15 days of notice of such to Impresse. If the amount owed by Impresse to VerticalNet was overpaid, the excess amount paid shall be returned by VerticalNet within 15 days of notice of such overpayment. VerticalNet shall give reasonable advance notice to Impresse of such audit and each audit shall be conducted in a manner that does not cause unreasonable disruption to the conduct of business by Impresse. The results of any such audit shall be deemed to be Confidential Information and may not be disclosed by either party or its certified public accountants except as may be necessary to enforce such party's rights.

4.9. INTEREST. All payments not paid by the date such payments are due shall bear interest from the due date to the date payments are actually paid at the lower of (i) 1% per month or (ii) the maximum rate permitted by law.

5.   TERMINATION AND RENEWAL

5.1. The Term of this Agreement shall begin on the Effective Date and shall end fifteen months therefrom.

6

5.2. Either party may terminate this Agreement immediately upon written notice to the other party in the event of any material breach of a term of this Agreement by such other party that remains uncured 30 days after written notice of such breach was received by such other party or, if the breach is not reasonably capable of cure within 30 days, such longer period, not to exceed 60 days, so long as the cure is commenced within the 30-day period and thereafter is diligently prosecuted to completion as soon as possible and in any event within 60 days.

5.3. Upon termination or expiration of this Agreement, (i) Impresse shall no longer have the right to use any VerticalNet Mark, (ii) VerticalNet shall no longer have the right to use any Impresse Mark; (iii) Impresse may no longer make any Co-Branded Content available for access and use through the Co-Branded Site; (iv) VerticalNet shall cease framing the Window in the Co-Branded Site; (v) VerticalNet shall remove the V-Solutions Link from the V-Solutions Area; and (vi) VerticalNet shall cease displaying or transmitting all Banners and Newsletters of Impresse.

5.4. Following expiration or termination of this Agreement, the terms and provisions of Article 4  [THE COMMERCIAL TERMS] above shall continue to govern Impresse's payment obligations for any payment obligations accruing during the term of this Agreement. Following termination, Impresse shall provide VerticalNet with a final accounting with respect to this Agreement and tender payment of amounts due under Article 4  [THE COMMERCIAL TERMS] at the next scheduled payment date.

6.   DISPUTE RESOLUTION

6.1. NEGOTIATION AND ESCALATION. If any controversy or claim arises relating to this Agreement, the parties will attempt in good faith to negotiate a solution to their differences, including progressively escalating any controversy or claim through senior levels of management. If negotiation does not result in a resolution within 30 days of the date one party first notifies the other of the controversy or claim, either party may resort to arbitration under Section 6.2  [ARBITRATION].

6.2. ARBITRATION. Any controversy or claim between the parties concerning any breach or alleged breach of this Agreement or performance or nonperformance of any obligation under this Agreement which cannot be resolved by negotiation will be resolved by binding arbitration under this Section 6.2  [ARBITRATION] and the then-current Commercial Rules and supervision of the American Arbitration Association (the AAA). If any part of this Section 6.2  [ARBITRATION] is held to be unenforceable, it will be severed and will not affect either the duty to arbitrate or any other part of this Section 6.2  [ARBITRATION]. The arbitration will be held before a sole disinterested arbitrator who is knowledgeable in business information and the Internet and experienced in handling commercial disputes. The arbitrator shall be appointed jointly by the parties hereto within 30 days following the date on which the arbitration is instituted. If the parties are unable to agree upon the arbitrator within such 30-day period, the AAA shall be instructed to select such arbitrator within 15 days thereafter. The arbitrator's award will be final and binding and may be entered in any court having jurisdiction. The arbitrator will not have the power to award punitive or exemplary damages, or any damages excluded by, or in excess of, any damage limitations expressed in this Agreement. Issues of arbitrability will be determined in accordance solely with the federal substantive and procedural laws relating to arbitration; in all other respects, the arbitrator will be obligated to apply and follow the substantive law of the State of Delaware.

7

6.3. EQUITABLE RELIEF. Notwithstanding anything to the contrary in this Agreement, in the event of an alleged violation of Article 7  [CONFIDENTIALITY] of this Agreement by either party, the party alleging such a violation may seek temporary and permanent injunctive or other appropriate equitable relief from any court of competent jurisdiction pending appointment of an arbitrator. The party requesting such relief shall simultaneously file a demand for arbitration of the dispute, and shall request that the AAA proceed under its rules for an expedited hearing.

6.4. COSTS. Unless the arbitrator, if any, determines otherwise, each party will bear its own attorneys' fees and other costs associated with the negotiation and arbitration provided for by this Article 6  [DISPUTE RESOLUTION], except that costs and expenses regarding the arbitrators shall be shared equally. If court proceedings to stay litigation or compel arbitration are necessary, the party who unsuccessfully opposes such proceedings will pay all associated costs, expenses and attorneys' fees that are reasonably incurred by the other party. To the extent that any claim in arbitration relates to the collection of amounts owed under Article 4  [THE COMMERCIAL TERMS], the party entitled to collect such amounts shall be entitled to recover all reasonable costs of collection, including expenses and attorneys' fees that are incurred.

6.5. TWO YEAR LIMITATION. Except for claims under Sections 9.4  [INDEMNIFICATION BY IMPRESSE] and 9.5  [INDEMNIFICATION BY VERTICALNET]

Source: IMPRESSE CORP, S-1/A, 3/22/2000





hereof, neither party may bring a claim or action regardless of form, arising out of or related to this Agreement, including any claim of fraud or misrepresentation, more than two years after the cause of action accrues or becomes known, whichever is later.

6.6. CONFIDENTIALITY. In order to facilitate the resolution of controversies or claims between the parties with respect to each party hereto, such controversies or claims, including details regarding negotiations, arbitration and settlement terms, shall be treated as Confidential Information of the other party hereto in accordance with Article 7  [CONFIDENTIALITY].

6.7. REMEDIAL MEASURES. In the event of (a) any material remediable breach of this Agreement by the other party which remains uncured 30 days after notice of such breach was received by the other party or (b) any material breach which cannot be cured, the non-breaching party may take reasonable remediable measures upon prior written notice and at the cost and expense of the breaching party without prejudice and in addition to any other rights arising from such breach. In addition, the non-breaching party shall take reasonable steps to mitigate damages arising out of such breach.

7.   CONFIDENTIALITY

7.1. CONFIDENTIALITY OBLIGATIONS. Except as permitted elsewhere under this Agreement, each party agrees to take Reasonable Steps (as defined below) (a) to receive and maintain the Confidential Information of the other party in confidence and (b) not to disclose such Confidential Information to any third parties, provided, the receiving party may disclose such Confidential Information to its employees, representatives and agents who have a need to know such information for purposes of carrying out the terms of this Agreement. Neither party hereto shall use all or any part of the Confidential Information of the other party for any purpose other than to perform its obligations under this Agreement. The parties will take Reasonable Steps (as defined below) to ensure that their employees, representatives and agents comply with this provision. As used herein, Reasonable Steps means at least the same degree of care that the

8

receiving party uses to protect its own Confidential Information, and, in no event, not less than reasonable care.

7.2. EXCLUSIONS. Confidential Information does not include information that (a) is or becomes publicly available through no fault of the receiving party; (b) was already known to the receiving party at the time it was disclosed to the receiving party, as evidenced by records of the receiving party; (c) is independently developed by employees of the receiving party who had no knowledge of or access to such information, as evidenced by records of the receiving party; (d) is received from a third party who is under no obligation of confidentiality to the disclosing party; or (e) must be disclosed pursuant to applicable laws, rules or regulations; provided, however, that the receiving party first gives the disclosing party notice and a reasonable opportunity to secure confidential protection of such Confidential Information.

7.3. TERMINATION. Subject to Section 10.11  [SURVIVAL], upon termination of this Agreement, all Confidential Information shall be returned to the disclosing party or, at the request of the disclosing party, destroyed unless otherwise specified or permitted elsewhere under this Agreement. Subject to Section 7.6  [USER DATA], the confidentiality obligations contained in this Article 7  [CONFIDENTIALITY] shall survive termination of this Agreement for a period of three years.

7.4. INJUNCTION. Each party acknowledges and agrees that the provisions of this Article 7  [CONFIDENTIALITY] are reasonable and necessary to protect the other party's interests in its Confidential Information, that any breach of the provisions of this Article 7  [CONFIDENTIALITY] may result in irreparable harm to such other party, and that the remedy at law for such breach may be inadequate. Accordingly, in the event of any breach or threatened breach of the provisions of this Article 7  [CONFIDENTIALITY] by a party hereto, the other party, in addition to any other relief available to it at law, in equity or otherwise, shall be entitled to seek temporary and permanent injunctive relief restraining the breaching party from engaging in and/or continuing any conduct that would constitute a breach of this Article 7  [CONFIDENTIALITY], without posting a bond or other security.

7.5. PUBLICITY. Neither party will originate any press release concerning the relationship between the parties or the transactions described in this Agreement without the prior written consent of the other party, which consent shall not be unreasonably withheld or delayed. Notwithstanding the foregoing, as soon as reasonably practicable following the Effective Date, VerticalNet and Impresse shall jointly issue a press release with respect to entering into this Agreement.

7.6. USER DATA. Impresse shall provide VerticalNet with User Data on each User that submits information through the Co-Branded Site by sending an email with such information to an email address designated by VerticalNet at the time the request occurs. User Data shall be maintained by each Party as Confidential Information of the other Party during the Term and 5 years thereafter, provided such User Data may be disclosed only as part of an aggregation or analysis of all User Data but not as independent data. Upon termination of the Agreement, VerticalNet and Impresse shall jointly own all User Data. Neither Party shall use the User Data other than in accordance with the VerticalNet privacy policy and all applicable laws during the Term and thereafter.

9

8.   REPRESENTATIONS AND WARRANTIES

8.1. REPRESENTATIONS AND WARRANTIES. Each party hereby represents, covenants and warrants that:

8.1.1. It has the corporate power to enter into this Agreement and to grant the rights and licenses granted herein and to otherwise perform this Agreement;

8.1.2. It is not a party to any agreement or understanding and knows of no law or regulation that would prohibit it from entering into and performing this Agreement or that would conflict with this Agreement;

8.1.3. When executed and delivered by it, this Agreement will constitute a legal, valid and binding obligation of it, enforceable against it in accordance with this Agreement's terms, except as enforcement may be limited by laws or regulations relating to bankruptcy, insolvency and creditors rights or by principles of equity;

Source: IMPRESSE CORP, S-1/A, 3/22/2000





8.1.4. The portions of the Co-Branded Site provided by such party are and will continue to be Year 2000 Compliant;

8.1.5. To the best of its knowledge, the portions of the Co-Branded Site provided by such party and its own Site do not and will not (i) contain any known viruses, Trojan Horse, worm or harmful code the purpose of which is to disable or interrupt the operating of a computer system or destroy, erase or otherwise harm any data, software or hardware, (ii) contain any false, misleading, libelous or defamatory statements, (iii) constitute an invasion of the rights of privacy or publicity of any third party, (iv) violate any applicable laws, rules and regulations or (v) infringe, violate or misappropriate any Intellectual Property Rights of any third party.

9.   DISCLAIMER OF WARRANTY, LIMITATION OF LIABILITY AND INDEMNIFICATION

9.1. DISCLAIMER OF WARRANTIES BY VERTICALNET. EXCEPT AS EXPRESSELY SET FORTH IN THIS AGREEMENT, VERTICALNET HEREBY DISCLAIMS ALL WARRANTIES, EXPRESS, IMPLIED OR STATUTORY, WITH RESPECT TO THE VERTICALNET SITES, THE V-SOLUTIONS AREA, THE V-SOLUTIONS LINK AND THE VERTICALNET AREA OF THE CO-BRANDED SITE, INCLUDING BUT NOT LIMITED TO ANY IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. VERTICALNET EXPRESSLY DISCLAIMS ANY AND ALL WARRANTIES AS TO THE USER INTERFACE OR USER EXPERIENCE ASSOCIATED WITH THE VERTICALNET SITES AND RESERVES THE RIGHT, IN ITS SOLE DISCRETION, TO MODIFY THE PLACEMENT OF ALL LINKS, URLS AND PROPRIETARY FEATURES; PROVIDED, HOWEVER, THAT IN THE EVENT VERTICALNET REDESIGNS THE USER INTERFACE, SUCH LINKS, URLS AND PROPRIETARY FEATURES SHALL RECEIVE MUTUALLY AGREEABLE PLACEMENT SUBSTANTIALLY SIMILAR TO THE ORIGINAL DESIGN.

10

9.2. DISCLAIMER OF WARRANTIES BY IMPRESSE. EXCEPT AS EXPRESSLY SET FORTH IN THIS AGREEMENT, IMPRESSE HEREBY DISCLAIMS ALL WARRANTIES, EXPRESS, IMPLIED OR STATUTORY, WITH RESPECT TO THE IMPRESSE AREA OF THE CO-BRANDED SITE AND THE IMPRESSE SITE, INCLUDING BUT NOT LIMITED TO ANY IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE.

9.3. LIMITATION OF LIABILITY. EXCEPT IN CONNECTION WITH A BREACH BY EITHER PARTY OF ARTICLE 7 OR SECTION 8.1.5  [REPRESENTATIONS AND WARRANTIES] (v) AND THE INDEMNIFICATION OBLIGATIONS OF IMPRESSE UNDER SECTION 9.4(i)(d)  [INDEMNIFICATION BY IMPRESSE] AND THE INDEMNIFICATION OBLIGATIONS OF VERTICALNET UNDER SECTION 9.5(i)(d)  [INDEMNIFICATION BY VERTICALNET], NEITHER PARTY WILL BE LIABLE FOR ANY SPECIAL, INDIRECT, CONSEQUENTIAL, EXEMPLARY OR INCIDENTAL DAMAGES ARISING OUT OF OR RELATED TO THIS AGREEMENT, HOWEVER CAUSED AND UNDER ANY THEORY OF LIABILITY (INCLUDING NEGLIGENCE), EVEN IF SUCH PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

9.4. INDEMNIFICATION BY IMPRESSE. Subject to Section 9.6  [PROCEDURE], Impresse shall (i) defend at its sole expense VerticalNet and its officers, directors, employees and agents from and against any action, suit, proceeding or investigation brought by a third party and caused by, relating to, based upon, arising out of or in connection with (a) any breach by Impresse of the representations, warranties or agreements made by it in Section 8 of this Agreement, (b) negligence, recklessness or intentional misconduct on the part of Impresse or its officers, directors, employees, agents or consultants, (c) any claim arising out of VerticalNet's authorized use or possession of the portions of the Co-Branded Site provided by Impresse and the Impresse Site as permitted by this Agreement; or (d) any claim that any portion of the Impresse Site or the Impresse Area of the Co-Branded Site violates, infringes or misappropriates any Intellectual Property Right of any third party and (ii) pay all authorized costs, expenses and disbursements incurred in such defense, and any damages, liabilities, obligations, penalties or judgments awarded in any such action, or any settlement amount agreed to by Impresse.

9.5. INDEMNIFICATION BY VERTICALNET. Subject to Section 9.6  [PROCEDURE], VerticalNet shall (i) defend at its sole expense Impresse and its officers, directors, employees and agents from and against any action, suit, proceeding or investigation brought by a third party, caused by, relating to, based upon, arising out of or in connection with (a) any breach by VerticalNet of the representations, warranties or agreements made by it in Section 8 of this Agreement, (b) negligence, recklessness or intentional misconduct on the part of VerticalNet or its officers, directors, employees, agents or consultants, (c) any claim arising out of Impresse's use or possession of the portions of the Co-Branded Site provided by VerticalNet and the VerticalNet Sites as permitted by this Agreement; or (d) any claim that any portion of the VerticalNet Site or the VerticalNet Area of the Co-Branded Site violates, infringes or misappropriates any Intellectual Property Right of any third party and (ii) pay all costs, expenses and disbursements authorized by the Indemnitor (defined below) incurred in such defense, and any damages, liabilities, obligations, penalties or judgments awarded in any such action, or any settlement amount agreed to by VerticalNet.

11

9.6. PROCEDURE. If any action shall be brought against a party in respect to which indemnity may be sought from the other party pursuant to the provisions of this Article 9  [DISCLAIMER OF WARRANTY, LIMITATION OF LI...], the party seeking indemnity (the Indemnitee) shall follow the procedures in this Section. If an Indemnitee receives any notice of a claim or other allegation with respect to which the other party (the Indemnitor) has an obligation of indemnity hereunder, then the Indemnitee will, within 15 days of receipt of such notice, give the Indemnitor written notice of such claim or allegation setting forth in reasonable detail the facts and circumstances surrounding the claim. The Indemnitee will not make any payment or incur any costs or expenses with respect to such claim, except as requested by the Indemnitor or as necessary to comply with this procedure. The Indemnitee will not make any admission of liability or take any other action that limits the ability of the Indemnitor to defend the case. The Indemnitor shall immediately assume the full control of the defense or settlement of such claim or allegation, including the selection and employment of counsel, and shall pay all authorized costs and expenses of such defense. The Indemnitee will fully cooperate, at the expense of the Indemnitor, in the defense or settlement of the claim. The Indemnitee shall have the right, at its own expense, to employ separate counsel and participate in the defense or settlement of the claim; provided that the Indemnitor shall have no liability for costs or expenses incurred by the Indemnitee, except to the extent authorized by the Indemnitor pursuant to this procedure.

9.7. ESSENTIAL PART OF BARGAIN. The parties acknowledge that the disclaimers and limitations set forth in this Article 9  [DISCLAIMER OF WARRANTY, LIMITATION OF LI...] are an essential element of this Agreement between the parties and that the parties would not have entered into this Agreement without such disclaimers and limitations.

Source: IMPRESSE CORP, S-1/A, 3/22/2000





10.  MISCELLANEOUS

10.1. INTELLECTUAL PROPERTY.

10.1.1. Except for the express rights granted to Impresse under this Agreement, Impresse acknowledges and agrees that the Intellectual Property of VerticalNet is and shall remain the sole property of VerticalNet and nothing in this Agreement shall confer in Impresse any right of ownership or license rights in VerticalNet's Intellectual Property. In addition, Impresse shall not now or in the future contest the validity of VerticalNet's ownership of its Intellectual Property; provided, however, that Impresse may contest the validity of VerticalNet's Intellectual Property in any proceeding brought against Impresse alleging infringement or misappropriation of VerticalNet's Intellectual Property.

10.1.2. Except for the express rights granted to VerticalNet under this Agreement, VerticalNet acknowledges and agrees that the Intellectual Property of Impresse is and shall remain the sole property of Impresse and nothing in this Agreement shall confer in VerticalNet any right of ownership or license rights in Impresse's Intellectual Property. In addition, VerticalNet shall not now or in the future contest the validity of Impresse's ownership of its Intellectual Property; provided, however, that VerticalNet may contest the validity of Impresse's Intellectual Property in any proceeding brought against VerticalNet alleging infringement or misappropriation of Impresse's Intellectual Property.

12

10.2. GOVERNING LAW. This Agreement shall be governed by and interpreted under the laws of the State of Delaware without regard to its conflicts of law provisions.

10.3. NO ASSIGNMENT. Except as otherwise set forth herein, neither party shall transfer, assign or cede any rights or delegate any obligations hereunder, in whole or in part, whether voluntarily or by operation of law, without the prior written consent of the other party, which consent may be withheld at the other party's reasonable business discretion; provided, however, that either party may transfer this Agreement without prior written consent of the other to an Affiliate of such party, or to the surviving party in a merger or consolidation, or to a purchaser of all or substantially all of its assets.

10.4. GOOD FAITH. The parties undertake to display to each other the utmost good faith, consistent with their respective rights and obligations set forth in this Agreement.

10.5. INDEPENDENT CONTRACTORS. In connection with this Agreement, each party is an independent contractor. This Agreement does not, and shall not be construed to, create an employer-employee, agency, joint venture or partnership relationship between the parties. Neither party shall have any authority to act for or to bind the other party in any way, to alter any of the terms or conditions of any of the other party's standard forms of invoices, sales agreements, warranties or otherwise, or to warrant or to execute agreements on behalf of the other or to represent that it is in any way responsible for the acts, debts, liabilities or omissions of the other party.

10.6. NOTICES. All notices, reports, payments and other communications required or permitted to be given under this Agreement (each, a Notice) shall be in writing and shall be given either by personal delivery against a signed receipt, by express delivery using a nationally recognized overnight courier, or by facsimile. All Notices shall be properly addressed as follows, or to such other addresses as may be specified in a Notice given hereunder:

IF TO VERTICALNET:

Attn: General Counsel VerticalNet, Inc. 700 Dresher Road, Suite 100 Horsham, Pennsylvania 19044 Tel No.: (215) 315-3200 Fax No.: (215) 784-1962

IF TO IMPRESSE:

Attn: Siva Kumar Impresse Corporation 1309 South Mary Avenue Sunnyvale, CA 94087 Phone No.: (408) 530-2022 Fax No.: (408) 245-8336

13

A Notice shall be deemed to be effective upon personal delivery or, if sent via overnight delivery, upon receipt thereof. A Notice sent via facsimile is deemed effective on the same day (or if such day is not a business day, then on the next succeeding business day) if such facsimile is sent before 3:00 p.m. Prevailing Eastern Time and on the next day (or if such day is not a business day, then on the next succeeding business day) if such Notice is sent after 3:00 p.m. Prevailing Eastern Time.

10.7. AMENDMENT OR MODIFICATION. No subsequent amendment, modification or waiver of any of the provisions of this Agreement shall be effective unless in writing and signed by the parties.

10.8. ENTIRE AGREEMENT. This Agreement sets out the entire agreement between the parties with respect to the subject matter of this Agreement and supersedes all prior agreements, proposals, arrangements and communications, whether oral or written, with respect to the subject matter hereof.

10.9. SEVERABILITY. If any provision of this Agreement is held by a tribunal of competent jurisdiction to be illegal, invalid, or otherwise unenforceable in any jurisdiction, then to the fullest extent permitted by law (a) the same shall not effect the other terms or provisions of this Agreement, (b) such term or provision shall be deemed modified to the extent necessary in the tribunal's opinion to render such term or provision enforceable, and the rights and obligations of the parties shall be construed and enforced accordingly, preserving to the fullest extent the intent and agreements of the parties set forth herein and (c) such finding of invalidity, illegality or unenforceability shall not affect the validity, legality or enforceability of

Source: IMPRESSE CORP, S-1/A, 3/22/2000





such term or provision in any other jurisdiction.

10.10. NO WAIVER. Failure to enforce any term of this Agreement is not a waiver of future enforcement of that or any other term. No term or provision of this Agreement will be deemed waived and no breach excused unless such waiver or excuse is in writing and signed by the party against whom enforcement of such waiver or excuse is sought.

10.11. SURVIVAL. Sections 5.3  [TERMINATION AND RENEWAL] and 5.4  [TERMINATION AND RENEWAL], and Articles 6  [DISPUTE RESOLUTION], 7, 8, 9 and 10, any payment obligations of the parties hereunder accruing prior to the date of termination; and any other provision herein expressly surviving termination or necessary to interpret the rights and obligations of the parties in connection with the termination of the term of this Agreement will survive the termination or expiration of this Agreement.

10.12. NO THIRD PARTY BENEFICIARIES. Nothing in this Agreement is intended to confer benefits, rights or remedies unto any person or entity other than the parties and their permitted successors and assigns.

10.13. WAIVER OF JURY TRIAL. Each party hereby irrevocably waives all rights a party may have to a trial by jury in any legal action or proceeding arising out of or in connection with this Agreement or the transactions contemplated hereby.

10.14. TITLES. The headings appearing at the beginning of the Sections contained in this Agreement have been inserted for identification and reference purposes only and shall not be used to determine the construction or interpretation of this Agreement. The nomenclature of the

14

defined terms in this Agreement shall only be used for the construction of this Agreement, and are not to be used for any other purpose, including, but not limited to, interpretation for accounting purposes.

10.15. FORCE MAJEURE. Neither party shall be held to be in breach of this Agreement by reason of a force majeure event, including, but not limited to, act of God, delay in transportation, fire, flood, earthquake, storm, war, act of a public enemy, civil commotion or any law, rule, regulation, order or other action by any public authority or any other matter reasonably beyond a party's control. To the extent failure to perform is caused by such a force majeure event, such party shall be excused from performance hereunder so long as such event continues to prevent such performance, and provided the non-performing party takes all reasonable steps to resume full performance.

10.16. COMPLIANCE WITH LAWS. Each party shall comply with all prevailing laws, rules and regulations and obtain all necessary approvals, consents and permits required by the applicable agencies of the government of the jurisdictions that apply to its activities or obligations under this Agreement.

10.17. EXECUTION IN COUNTERPARTS, FACSIMILES. This Agreement may be executed in one or more counterparts, each of which when delivered to the other party shall be deemed an original and all of which together shall constitute one and the same instrument. This Agreement shall become binding when any one or more counterparts hereof, individually or taken together, bear the signatures of both parties hereto. For the purposes hereof, a facsimile copy of this Agreement, including the signature pages hereto, shall be deemed an original.

IN WITNESS WHEREOF, the parties to the Agreement by their duly authorized representatives have executed this Agreement as of the date first written above.

VERTICALNET, INC.                              IMPRESSE CORPORATION

By: /s/ Michael Hagon                         By: /s/ Siva Kumar    -------------------------------               ----------------------------

Name:                                         Name:      -----------------------------                 --------------------------

Title:                                        Title:       ----------------------------                  -------------------------

15

Source: IMPRESSE CORP, S-1/A, 3/22/2000 
Question: Highlight the parts (if any) of this contract related to Covenant Not To Sue that should be reviewed by a lawyer. Details: Is a party restricted from contesting the validity of the counterparty’s ownership of intellectual property or otherwise bringing a claim against the counterparty for matters unrelated to the contract?
Example Output: Except for claims under Sections 9.4  [INDEMNIFICATION BY IMPRESSE] and 9.5  [INDEMNIFICATION BY VERTICALNET]

Example Input: Exhibit 10.1

JOINT VENTURE AGREEMENT THIS JOINT VENTURE AGREEMENT (the Agreement) made and entered into this 20th day of Friday, March 2020 (the Execution Date), BETWEEN: BorrowMoney.com, inc of 512 Bayshore DR, suite 201 Fort Lauderdale FL 33304, and JVLS, LLC dba Vaccines 2Go of 4060 Johns Creek Parkway Suite H Suwanee, GA 30024 (individually the Member and collectively the Members). BACKGROUND: A. The Members wish to enter into an association of mutual benefit and agree to jointly invest and set up a joint venture enterprise. B. This Agreement sets out the terms and conditions governing this association. IN CONSIDERATION OF and as a condition of the Members entering into this Agreement and other valuable consideration, the receipt and sufficiency of which consideration is acknowledged, the Members agree as follows: Formation 1. By this Agreement the Members enter into a joint venture (the Venture) in accordance with the laws of the State of Florida. The rights and obligations of the Members will be as stated in the applicable legislation of the State of Florida (the Act) except as otherwise provided here. Name 2. The business name of the Venture will be BM&V2GO. Page 1 of 13





Purpose 3. The exclusive purpose of the Venture (the Purpose) will be IT Development. internet Back office Maintenance And Deployment of medical Service. Term 4. The duration of this Venture (the Term) will begin on March 1, 2020 and continue in full force and effect until February 28, 2025 or as otherwise provided in this Agreement. 5. The Term may be extended with the unanimous consent of all Members. Place of Business 6. The principal office of the business of the Venture will be located at 512 Bayshore Drive Suite 201 Fort Lauderdale, FL 33304 or such other place as the Members may from time to time designate. Business Management 7. The following managers (the Managers) have been appointed by the Members to manage the Venture: ● Aaldo PIscitello ● Jody Stewart 8. Except as otherwise provided in this Agreement, the individual Managers may be appointed, replaced, or removed upon unanimous consent of the Members. 9. The Managers will have a primary duty to the best interest of the Venture and not directly to any individual Member. 10. Within the limits of the Purpose of the Venture and the terms of this Agreement, the Managers, acting jointly, will have full authority to bind the Members in all matters relating to the direction, control and management of the Venture. Conduct and actions of the Managers will be dictated by policy and procedure established by the Members. Authority to bind the Venture in contract or in any third party business relation lies exclusively with the Managers, acting jointly. 11. The Managers will jointly decide major issues concerning the Venture. Where Managers are unable to reach agreement in deciding major issues, approval by a majority vote of the Members at a regular or special meeting will be required. Page 2 of 13





Management Duties 12. Except as otherwise specified in this agreement, the duties and obligations of the Managers in relation to the Venture will include the following: a. managing the day to day business of the Venture; b. monitoring, controlling and directing the financial, business and operational affairs of the Venture; c. proper maintenance of books of account and financial records according to accepted accounting practices; d. monitoring, analyzing and acting on all issues over which it would have express or implied authority according to this Agreement; and e. all responsibilities attached to hiring of production and administration staff including any required labor negotiations, and all responsibilities attached to hiring of third party contractors. Member Duties 13. Each Member will be responsible for its respective duties as follows:

Page 3 of 13





Member Duties Description

BorrowMoney.com, inc

*HTML code, build, deploy and maintain all technical aspect requirements including a database for medical dispatch personal & product service as needed, including activity information, data storage and backup. provided by three qualified assigned Borrowmoney.com, inc. employees/personal

JVLS, LLC dba Vaccines 2Go

$60,000.00 USD From Monthly Government , City And State, And Or Private Awarded Contracts. Plus (10%) Of Any Generated Gross Revenue From Awarded Contract, In Addition to The Total Contributions. 14. Duties of Members may be amended, from time to time, by decision of the Members, provided that the Members' interests are not affected except with the unanimous consent of the Members. Capital Contributions 15. Each of the Members has contributed to the capital of the Venture, in cash or property in agreed upon value, as follows (the Capital Contribution): Member Contribution Description Agreed Value

BorrowMoney.com, inc 1, 500 square feet of Leased/rent office Space Includingspecified Description of duty* $3,500,000.00 USD

JVLS, LLC dba Vaccines 2Go

$60,000.00 USD From Monthly Government , City And State, And Or Private Awarded Contracts. Plus (10%) Of Any Generated Gross Revenue, In  Add i t i on  to  The  To ta l Contributions.

$3,500,000.00 USD

16. All Members will contribute their respective Capital Contributions fully and on time.

Page 4 of 13





Withdrawal of Capital 17. No Member will have the right to demand or withdraw any portion of their capital contribution without the express written consent of the remaining Members. 18. The Members will not be personally liable for the return of all or part of the Capital Contributions of a Member, except as otherwise provided in this Agreement. Additional Capital 19. Capital Contributions may be amended from time to time, according to the requirements of the Venture, by decision of the Members as recommended by the Managers. Where Members' interests are affected, additional capital contributions (the Additional Capital Contributions) must have the unanimous consent of the Members. 20. Any advance of money to the Venture by any Member in excess of the amounts provided for in this Agreement or subsequently agreed to as an Additional Capital Contribution will be deemed a debt due from the Venture rather than an increase in Capital Contribution of the Member. This liability will be repaid with interest at such rates and times to be determined by a majority of the Members. This liability will not entitle the lending Member to a greater voting power. Such debts may have preference or priority over any other payments to Members as may be determined by a majority of the Members. Capital Accounts 21. An individual capital account will be maintained for each Member and their initial Capital Contribution will be credited to this account. Any additional, approved contributions to the Venture's capital made by a Member will be credited to that Member's individual Capital Account. Interest on Capital 22. No borrowing charge or loan interest will be due or payable to any Member on any Capital Contribution or on their Capital Account despite any disproportion that may from time to time arise among the Capital Accounts of the Members. Page 5 of 13





Books of Account 23. Accurate and complete books of account of the transactions of the Venture will be kept in accordance with generally accepted accounting principles (GAAP) and at all reasonable times will be available and open to inspection and examination by any Member. The books and records of the Venture will reflect all the Venture's transactions and will be appropriate and adequate for the business conducted by the Venture. Banking and Venture Funds 24. The funds of the Venture will be placed in such investments and banking accounts as will be designated by the Members. Venture funds will be held in the name of the Venture and will not be commingled with those of any other person or entity. Member Meetings 25. Regular Member meetings will be held quarterly. Minutes of the meetings will be maintained on file. 26. Any Member can call a special meeting to resolve urgent issues that require a vote and that cannot wait for the next regularly scheduled meeting. When calling a special meeting, all Members must be provided with reasonable notice. Where a special meeting has been called, the meeting will be restricted to the specific purpose for which the meeting was called. 27. All meetings will be held at a time and in a location that is reasonable, convenient and practical considering the situation of all Members. 28. Any vote required by the Members will be determined such that each Member receives one vote carrying equal weight. Amendments 29. This Agreement may be amended only with the unanimous consent of all Members. Admitting a new Member 30. New Members may be admitted into the Venture only with the unanimous consent of the existing Members. The new Member agrees to be bound by all the covenants, terms, and conditions of this Agreement, inclusive of all current and future amendments. Further, a new Member will execute such documents as are needed or required for this admission. Any new Member will receive a business interest in the Venture as determined by all other Members. Page 6 of 13





Dissociation of a Member 31. Where a Member is in breach of this Agreement and that Member has not remedied the breach on notice from the Venture and after a reasonable period then the remaining Members will have the right to terminate this Agreement with regard to that individual defaulting Member (an Involuntary Withdrawal) and take whatever action necessary to protect the interests of the Venture. 32. If the Venture is harmed as the result of an individual Member's action or failure to act, then that individual Member will be liable for that harm. If more than one Member is at fault then they will be jointly and severally liable for that harm. 33. Each Member will indemnify the remaining Members against all losses, costs and claims that may arise in the event of the Venture being terminated as a result of breach of the Agreement by that Member. 34. If a Member is placed in bankruptcy, or withdraws voluntarily from the Venture, or if there is an Operation of Law against a Member, the other Members will be entitled to proceed as if the Member had breached this Agreement. 35. Distribution of any amount owing to a dissociated Member will be made according to the percentage of ownership as described in the Valuation of Interest or as otherwise may be agreed in writing. Dissolution of the Joint Venture 36. The Venture will be dissolved and its assets liquidated in the event of any of the following: a. the Term expires and is not extended; b. a unanimous vote by the Members to dissolve the Venture; c. on satisfaction of the Purpose; d. loss or incapacity through any means of substantially all of the Venture's assets; or e. where only one Member remains. Page 7 of 13





Liquidation 37. On dissolution, the Venture will be liquidated promptly and within a reasonable time. 38. On the liquidation of the Venture assets, distribution of any amounts to Members will be made in proportion to their respective capital accounts or as otherwise may be agreed in writing. Valuation of Interest 39. In the absence of a written agreement setting a value, the value of the Venture will be determined based on the fair market value appraisal of all Venture assets (less liabilities) in accordance with generally accepted accounting principles (GAAP) by an independent accounting firm agreed to by all Members. An appraiser will be appointed within a reasonable period of the date of withdrawal or dissolution. The results of the appraisal will be binding on all Members. A withdrawing Member's interest will be based on the proportion of their respective capital account less any outstanding liabilities a Member may have to the Venture. The intent of this section is to ensure the survival of the Venture despite the withdrawal of any individual Member. 40. No allowance will be made for goodwill, trade name, patents or other intangible assets, except where those assets have been reflected on the Venture books immediately prior to valuation. Transfer of Member Interest 41. A Member may assign their proprietary assets and their rights in distribution interest in the Venture. Such assignment will only include that Member's economic rights and interests and will not include any other rights of that Member nor will it include an automatic admission as a Member of the Venture or the right to exercise any management or voting interests. A Member who assigns any or all of their Venture interest to any third party will relinquish their status as Member including all management and voting rights. Assignment of Member status, under this clause, including any management and voting interests, will require the consent of all the remaining Members. Page 8 of 13





Management Voting 42. Any management vote required will be determined such that each Manager receives one vote carrying equal weight. Force Majeure 43. A Member will be free of liability to the Venture where the Member is prevented from executing their obligations under this Agreement in whole or in part due to force majeure where the Member has communicated the circumstance of that event to any and all other Members and taken any and all appropriate action to mitigate that event. Force majeure will include, but not be limited to, earthquake, typhoon, flood, fire, and war or any other unforeseen and uncontrollable event. Duty of Loyalty 44. Provided a Member has the consent of the majority of the other Members, the Members to this Agreement and their respective affiliates may have interests in businesses other than the Venture. Neither the Venture nor any other Member will have any rights to the assets, income or profits of any such business, venture or transaction. Any and all businesses, ventures or transactions with any appearance of conflict of interest must be fully disclosed to all other Members. Failure to disclose any potential conflicts of interest will be deemed an Involuntary Withdrawal by the offending Member and may be treated accordingly by the remaining Members. Confidentiality 45. All matters relating to this Agreement and the Venture will be treated by the Members as confidential and no Member will disclose or allow to be disclosed any Venture matter or matters, directly or indirectly, to any third party without the prior written approval of all Members except where the information properly comes into the public domain. 46. This section will survive for one year after the expiration or termination of this Agreement or dissolution of the Venture. Language 47. The Members expressly state that the English language is to be the language of choice for this Agreement and all other notices and agreements required by the Venture. Page 9 of 13





Insurance 48. The Venture will insure all its assets against loss where reasonable and standard practice in the industry. Indemnification 49. Each Member will be indemnified and held harmless by the Venture from any and all harm or damages of any nature relating to the Member's participation in Venture affairs except where such harm or damages results from gross negligence or willful misconduct on the part of the Member. Liability 50. No Member will be liable to the Venture or to any other Member for any error in judgment or any act or failure to act where made in good faith. The Member will be liable for any and all acts or failures to act resulting from gross negligence or willful misconduct. Liability Insurance 51. The Venture may acquire insurance on behalf of any Member, employee, agent or other person engaged in the business interest of the Venture against any liability asserted against them or incurred by them while acting in good faith on behalf of the Venture. Covenant of Good Faith 52. Members will use their best efforts, fairly and in good faith to facilitate the success of the Venture. Joint Venture Property 53. Where allowed by statute, title to all Venture property, including intellectual property, will remain in the name of the Venture. Where joint ventures are not recognized by statute as separate legal entities, Venture property, including intellectual property, will be held in the name of one or more Members. In all cases Venture property will be applied by the Members exclusively for the benefit and purposes of the Venture and in accordance with this Agreement. Jurisdiction 54. The Members submit to the jurisdiction of the courts of the State of Florida for the enforcement of this Agreement and for any arbitration award or decision arising from this Agreement. Page 10 of 13





Mediation and Arbitration 55. In the event a dispute arises out of, or in connection with, this Agreement, the Members will attempt to resolve the dispute through friendly consultation. 56. If the dispute is not resolved within a reasonable period then any or all outstanding issues may be submitted to mediation in accordance with any statutory rules of mediation. If mediation is not successful in resolving the entire dispute or is unavailable, any outstanding issues will be submitted to final and binding arbitration in accordance with the laws of the State of Florida. The arbitrator's award will be final, and judgment may be entered upon it by any court having jurisdiction within the State of Florida. Warranties 57. All Members represent and warrant that they have all authority, licenses and permits to execute and perform this Agreement and their obligations under this Agreement and that the representative of each Member has been fully authorized to execute this Agreement. 58. Each Member represents and warrants that this Agreement is not in violation of any and all agreements and constitutional documents of the individual Member. Definitions 59. For the purpose of this Agreement, the following terms are defined as follows: a. Capital Contributions The capital contribution to the Venture actually made by the Members, including property, cash and any additional capital contributions made. b. Majority Vote A Majority Vote is any amount greater than one-half of the authorized votes. c. Operation of Law The Operation of Law means rights or duties that are cast upon a party by the law, without any act or agreement on the part of the individual including but not limited to an assignment for the benefit of creditors, a divorce, or a bankruptcy. Page 11 of 13





Miscellaneous 60. This Venture is termed a contractual joint venture and will not constitute a partnership. Members will provide services to one another on an arms' length basis while remaining independent business entities. There will be no pooling of profits and losses. Each Member is responsible only for its own actions and no Member is an agent for any other Member. Members will not be jointly or severally liable for the actions of the other Members. 61. Time is of the essence in this Agreement. 62. This Agreement may be executed in counterparts. Facsimile signatures are binding and are considered to be original signatures. 63. Headings are inserted for the convenience of the Members only and are not to be considered when interpreting this Agreement. Words in the singular mean and include the plural and vice versa. Words in the masculine gender include the feminine gender and vice versa. Words in the neuter gender include the masculine gender and the feminine gender and vice versa. 64. If any term, covenant, condition or provision of this Agreement is held by a court of competent jurisdiction to be invalid, void or unenforceable, it is the Members' intent that such provision be reduced in scope by the court only to the extent deemed necessary by that court to render the provision reasonable and enforceable and the remainder of the provisions of this Agreement will in no way be affected, impaired or invalidated as a result. 65. This Agreement contains the entire agreement between the Members. All negotiations and understandings have been included in this Agreement. Statements or representations which may have been made by any Member in the negotiation stages of this Agreement may in some way be inconsistent with this final written Agreement. All such statements are declared to be of no value in this Agreement. Only the written terms of this Agreement will bind the Members. 66. This Agreement and the terms and conditions contained in this Agreement apply to and are binding upon the Member's successors, assigns, executors, administrators, beneficiaries, and representatives. 67. Any notices or delivery required here will be deemed completed when hand-delivered, delivered by agent, or seven (7) days after being placed in the post, postage prepaid, to the Members at the addresses contained in this Agreement or as the Members may later designate in writing. Page 12 of 13





68. All of the rights, remedies and benefits provided by this Agreement will be cumulative and will not be exclusive of any other such rights, remedies and benefits allowed by law. IN WITNESS WHEREOF the Members have duly affixed their signatures under hand and seal on this 20th day of March 2020. BorrowMoney.com, inc (Member) Per: /s/ Aldo Piscitello (SEAL) Aldo Piscitello President JVLS, LLC dba Vaccines 2Go (Member) Per: /s/ Jody Stewart Jody Stewart (Mar 20, 2020) (SEAL) Jody Stewart Page 13 of 13 
Question: Highlight the parts (if any) of this contract related to Insurance that should be reviewed by a lawyer. Details: Is there a requirement for insurance that must be maintained by one party for the benefit of the counterparty?
Example Output:
The Venture may acquire insurance on behalf of any Member, employee, agent or other person engaged in the business interest of the Venture against any liability asserted against them or incurred by them while acting in good faith on behalf of the Venture.