In this task, you're given a passage that represents a legal contract or clause between multiple parties, followed by a question that needs to be answered. Based on the paragraph, you must write the index where the answer starts. If multiple answers seem to exist, write the index of the answer that is the most plausible. If multiple indices must be used to answer the question, the output should be a common separated list of indices.

Input: Consider Input: Exhibit 10.1 MANUFACTURING, DESIGN AND MARKETING AGREEMENT This MANUFACTURING, DESIGN AND MARKETING AGREEMENT (this Agreement) is entered into by and between Zounds Hearing, Inc., a Delaware corporation (Subcontractor) and InnerScope Hearing Technologies, Inc., a Nevada corporation, (the Manufacturer) Manufacturer dated effective October 3, 2018 (the Effective Date). Subcontractor and Manufacturer may also be referred to herein individually as Party or collectively as the Parties. RECITALS WHEREAS, Subcontractor currently is the registered manufacturer of hearing aids and related components and accessories (the Zounds Products) that are sold under the Subcontractor's brand names through various marketing and distribution channels. WHEREAS the Parties desire to enter an agreement whereby the Subcontractor as the Manufacturer's subcontractor will provide design, technology, manufacturing and supply chain services to the Manufacturer to enable the Manufacturer to manufacture comparable hearing aids and related components and accessories to be sold under Manufacturer's exclusive brand names (the Manufacturer's Products) through the Manufacturer's various marketing and distribution channels. WHEREAS, the Parties also desire to enter into a lease agreement of Subcontractor's current Chandler, Arizona facility that provides the Manufacturer an FDA medical device facility for the Manufacturer's Products. WHEREAS, the Parties also desire to enter into an agreement that provides for the joint marketing and sale of each other's products. NOW, THEREFORE, in consideration of the promises and covenants contained herein, the Parties hereby agree as follows: 1. Term. Subject to earlier termination as provided in this Agreement, the initial term of this Agreement shall be for a period beginning on the Effective Date and ending ten (10) years thereafter unless this Agreement is terminated earlier as provided herein. This Agreement will renew automatically thereafter for successive one-year terms unless and until one Party gives notification of termination with at least sixty (60) days written notice. All orders placed under this Agreement must be placed prior to the expiration or termination of this Agreement.

2. Technology Access Fee. Manufacturer will pay Subcontractor One Million and No/100 USD ($1,000,000) (the Technology Access Fee). The Technology Access Fee will be paid in two equal installments of $500,000 each. The first installment will be due thirty (30) days following the Effective Date and the second installment will be due sixty (60) days following the Effective Date.

3. Orders for Manufacturer's Products to be Manufactured by Subcontractor

3.1 Purchase Orders: Excess Inventory. Manufacturer shall provide to Subcontractor a purchase order setting forth the proposed quantity of Manufacturer's Products to be purchased by Manufacturer and delivery dates, which purchase order will be subject to written acceptance by Subcontractor. All purchase orders are non-cancellable, and the Manufacturer shall pay for the purchaser orders as follows: (i) for purchase orders for less than or equal to a total of five hundred (500) units in any given calendar month, payment of fifty percent (50%) of Product Cost (as defined below) shall be made in full at the time the order is placed and the remaining balance paid in full before the Manufacturer's Products are shipped; and (ii) for purchase orders for more than five hundred (500) units in any given calendar month, payment of one hundred percent (100%) of Product Cost shall be made in full at the time the order is placed. Manufacturer's purchase orders accepted by Subcontractor and any forecast provided to Subcontractor by Manufacturer will constitute authorization for Subcontractor to procure product components to manufacture the Manufacturer's Products covered by such purchase orders based on their lead times. Subcontractor will advise Manufacturer of the lead time of components contained within their order and any forecast and Manufacturer will pay for the components prior to the Subcontractor placing orders for the components.

3.2 Contract Formation: Acceptance and Entire Agreement. Each time Manufacturer submits an order for Manufacturer's Products and Subcontractor accepts the order or ships the ordered Manufacturer's Products to Manufacturer, a new contract is formed consisting of this Agreement, the quantities and delivery dates specified in the order and the prices then offered by Subcontractor. ACCEPTANCE OF MANUFACTURER'S ORDER IS EXPRESSLY LIMITED TO THE TERMS AND CONDITIONS OF THIS AGREEMENT, NOTWITHSTANDING ANY ORAL OR WRITTEN STATEMENT MADE BY MANUFACTURER, AND DOES NOT IN ANY WAY WHATSOEVER CONSTITUTE ACCEPTANCE OF MANUFACTURER'S TERMS AND CONDITIONS EXCEPT AS SET FORTH IN THE TERMS OF THIS AGREEMENT. NO TERMS AND CONDITIONS CONTAINED IN ANY PURCHASE ORDER FORM, WHETHER PROVIDED BY MANUFACTURER OR SUBCONTRACTOR, WILL BECOME A PART OF THE CONTRACT AND THIS CONTRACT WILL GOVERN ALL PURCHASES. Manufacturer's acceptance of or payment for Manufacturer's Products that Manufacturer has not ordered creates a contract comprised of this Agreement, the quantities of Manufacturer's Products accepted or paid for, and the prices then offered by Subcontractor. This Agreement shall constitute the entire agreement with respect to any contract formed and shall not be altered, amended, supplemented or canceled without the express written agreement of both Manufacturer and Subcontractor.





3.3 Product Prices. Pricing shall be the actual cost of the manufacturing of each Manufacturer's Product plus the proportional allocation of the costs of Subcontractor's manufacturing, engineering, and supply chain overhead, as mutually agreed by the Parties (the Product Cost). Title of the product will transfer to the Manufacturer at the shipping dock of the manufacturing facility. Manufacturer will be responsible for shipping costs. Manufacturer shall pay any taxes incurred in the manufacture of Manufacturer's Products, including any taxes incurred as a result of purchasing components or maintaining inventory. In addition to the Royalties paid under this Agreement to the Subcontractor, Manufacturer shall pay any other third-party royalties for technology that are required to manufacture the Manufacturer's Products for their intended purpose. As of the date of this Agreement neither Party is aware of any third-party royalties for technology that Manufacturer would be liable to pay. Subcontractor will provide Manufacturer with documentation substantiating any Product Cost variance upon request.

3.4 Cost Reductions. Potential Product Cost reductions as a result of materials pricing will be reviewed and implemented periodically as mutually agreed and passed on to the Manufacturer. Product Cost reductions resulting from engineering changes or other changes, initiated by Manufacturer, that would impact either Product Costs or process changes at Subcontractor will be implemented at an agreed upon time. Manufacturer will be responsible for their proportionate share of any Product Cost reduction that is a result of engineering investment by the Subcontractor. If the Manufacturer does not pay its proportionate share, the Manufacturer will pay the Product Cost as if the cost reduction had not been made (i.e., the Product Cost prior to the cost reduction as if the cost reduction were not made). The Subcontractor will list the new Product Cost and a line item for engineering investment that accounts for the difference.

3.5 Royalties. In addition to paying the Product Costs of Manufacturer's Products, Manufacturer shall also pay to Subcontractor the following royalty payments (each a Royalty and collectively the Royalties) for each of Manufacturer's Product purchased under this Agreement. Royalties shall be paid 50% at time of shipping and the remaining balance of 50% due in 15-days after the Manufacturer's Products have shipped from the manufacturing facility. a) Non-Rechargeable Products. For Manufacturer's Products that are non-rechargeable, Manufacturer shall pay Subcontractor a Royalty equal to the higher of (i) eighty percent (80.0%) of the Product Cost; and (ii) $80 per unit. b) Rechargeable Products. For Manufacturer's Products that are rechargeable, Manufacturer shall pay Subcontractor a Royalty equal to the higher of (i) one hundred percent (100.0%) of the Product Cost; and (ii) $100 per unit. 3.6 Zounds' Products and Manufacturers Products Built to Manufacturer's Specifications. Subject to Section 7 below, Subcontractor agrees to manufacture Manufacturer's Products (i) that are identical to Zounds' Products allowing Manufacturer to utilize Subcontractor's existing product designs and features and/ or (ii) to specifications provided by Manufacturer from time to time with approval of such changes by Subcontractor. Any advice given by Subcontractor to Manufacturer before or after delivery of Products built to Manufacturer's specifications is based solely upon the information available to Subcontractor, and the use of such advice by Manufacturer is solely and entirely at Manufacturer's own risk. Manufacturer represents and warrants that it has independently determined the fitness, need, usefulness, and applicability of the Manufacturer's Products built to Manufacturer's specifications it has ordered and does not rely on any representation of Subcontractor in that regard.

3.7 Engineering Services and Design Changes. Manufacturer may elect to utilize Subcontractor's design engineering resources (the Engineering and Design Services) to further customize Manufacturer's Products. The cost of Engineering and Design Services to be paid by Manufacturer will be agreed to in a written document setting forth the scope, timing and other terms of such Engineering and Design Services executed by the Parties prior to any services being provided by Subcontractor. Subject to the written agreement of the parties with respect to any resulting change in price, delivery schedule and other terms, Subcontractor will accept design changes (i.e., Engineering Change Orders or ECO's) according to Manufacturer's instructions.

3.8 Tooling, Setup and Non-Recurring Engineering (NRE) Charges. Subcontractor agrees to provide Manufacturer with a quote for any one-time tooling, setup or NRE charges payable by Manufacturer as a result of a change in design requested by Manufacturer, change in minimum quantity requirements by Manufacturer as originally quoted by Subcontractor, or an addition to the Manufacturer's Products purchased under this Agreement requested by Manufacturer. If Manufacturer elects to proceed with the design change, minimum quantity requirements change or addition as specified in Subcontractor's quote, Manufacturer will provide Subcontractor with written acceptance of Subcontractor's quoted terms.

3.9 Inventory Reports. Subcontractor agrees to report its inventory position to Manufacturer on a monthly basis, including the following information: quantity of raw material, work in process and any open orders that cannot be cancelled to the supplier lead time. The report will specifically identify any material on hand or on order where the quantity exceeds the agreed three (3) month forward looking forecast plus safety stock as agreed upon by Subcontractor and Manufacturer. The Subcontractor and Manufacturer will review inventory levels and safety stocks quarterly.

4. Delivery and Shipping. The agreed upon delivery dates are based on the Subcontractor's projected lead time, current inventory, commitments and Subcontractor's advice. Manufacturer agrees and acknowledges that all shipment dates are firm delivery dates. All shipments shall be F.O.B. the manufacturing facility unless otherwise mutually agreed upon in writing. The method and route of shipment shall be at Subcontractor's discretion, unless Manufacturer supplies instructions in writing at least five days prior to shipment. In addition to the purchase price, Manufacturer shall pay any and all transportation charges (including insurance). The risk of loss of and title to the Manufacturer's Products pass to Manufacturer upon the receipt of the Manufacturer's Products by the carrier. Subcontractor is not responsible for any installation of Manufacturer's Products sold





hereunder or delays caused by Manufacturer-specified suppliers.

5. Leased Space Agreement. Manufacturer will lease from Subcontractor a well-defined space for Manufacturer's Products within the Subcontractor's current FDA registered manufacturer's facility. Subcontractor is solely responsible for maintaining all aspects of such leased space including but not limited to; (i) segregation of Manufacturer's Products with all Manufacturer's Products clearly segregated and marked; and (ii) meeting all necessary requirements deemed appropriate by the FDA and any regulatory authorities for a medical device manufacturer's facility. Subcontractor will be also solely responsible for remaining in good standings at all times with all regulatory authorities including but not limited to the standards set forth by the FDA for medical device manufacturing facilities. The Manufacturer may list the address of the Subcontractor's current FDA registered manufacturer's facility as the Manufacturer's own FDA approved manufacturer's facility for the Manufacturer's Products. The terms of such lease agreement will be mutually agreed to by the Parties in a separate document.

6. Payment Terms. Upon Subcontractor's approval and acceptance of a production forecast provided by Manufacturer, Manufacturer's payment for Manufacturer's Products will be due when forecasted materials or components must be ordered by the Subcontractor as set forth in Section 3 above. A schedule of the forecast payables will be provided by the Subcontractor to the Manufacturer based on the approved forecast. Components and products will only be procured and/or manufactured once payment has been received. All payments will be made by electronic wire transfer and all of the appropriate forms will need to be signed so that this can happen efficiently. Alternately, payments can be made to Subcontractor's address as shown Subcontractor's invoice. No offsets are allowed to be taken by either Party. Manufacturer represents that all sales to Manufacturer under this Agreement are sales for use in production or resale; therefore no sales, use, excise or other taxes are due as a result of such sales and Manufacturer will be responsible for payment of any such taxes. A copy of the Manufacturer's resale certificate will be provided by Manufacturer within 15-days of the Effective Date.

7. Limited Warranty; Nonconforming Products. Since Manufacturer is paying the actual manufacturing cost of the product, Supplier has not reserved for any warranty related costs. The Manufacturer acknowledges that it is solely responsible for any warranty costs associated with Manufacturer's Products. Should any nonconformities be detected during or after the manufacturing process, Subcontractor will assist Manufacturer in resolving any quality issues with the suppliers. Subcontractor will provide support to Manufacturer to train Manufacturer's employees to repair the non-conforming products as appropriate. Upon Manufacturer's request, Subcontractor will provide repair services for a fee equal to the actual cost of these services. In the event Manufacturer in good faith believes that Manufacturer's Products are nonconforming under the specifications agreed to among the Parties (the Standards), Manufacturer shall give written notice to Subcontractor specifying in detail the nonconformity within thirty (30) days of Manufacturer's receipt of such Manufacturer's Products. Upon Manufacturer's request, Subcontractor will facilitate such Manufacturer's Products being repaired or replaced, Manufacturer must return the Manufacturer's Products to Subcontractor, transportation charges prepaid by Manufacturer, within fifteen (15) days of the end of such thirty (30) date notice period. Notwithstanding anything else in this Agreement, Subcontractor makes no representations or warranties whatsoever with respect to: (i) any materials, components or subassemblies; (ii) defects resulting from the Specifications or the design of the Manufacturer's Products; (iii) Manufacturer's Product that has been abused, damaged, altered or misused by any person or entity after title passes to Manufacturer; (iv) first articles, prototypes, pre-production units, test units or other similar Manufacturer's Products; or (v) defects resulting from tooling, designs or instructions produced or supplied by Manufacturer. Manufacturer shall be liable for costs or expenses incurred by Subcontractor related to the foregoing exclusions to Subcontractor's express limited warranty. If Subcontractor determines that the Manufacturer's Products are nonconforming under the Standards, Subcontractor, shall work with their vendors to rework the Manufacturer's Products or otherwise replace the Manufacturer's Products. Manufacturer shall be liable for the cost of rework or replacement and all associated costs therewith including, without limitation, transportation charges and inspection fees. If requested by the Manufacturer, Subcontractor will provide a cause of failure, a failure analysis provided in Subcontractor's standard format and correction action.





MANUFACTURER ACKNOWLEDGES THAT SUBCONTRACTOR IS NOT THE MANUFACTURER OF MOST, IF NOT ALL, OF THE COMPONENTS OF THE MANUFACTURER'S PRODUCTS OR ANY THIRD PARTY MANUFACTURER'S AGENT. SUBCONTRACTOR MAKES NO REPRESENTATIONS OR WARRANTIES IN CONNECTION WITH THE PRODUCTS OR COMPONENTS THEREOF WHICH SUBCONTRACTOR DID NOT MANUFACTURE. FURTHER, SUBCONTRACTOR SPECIFICALLY DISCLAIMS ALL WARRANTIES, EXPRESS OR IMPLIED, IN FACT OR BY OPERATION OF LAW OR OTHERWISE, CONTAINED IN OR DERIVED FROM THIS AGREEMENT, ANY ORDER, OR IN ANY OTHER MATERIALS, BROCHURES, PRESENTATIONS, SAMPLES, MODELS OR OTHER DOCUMENTATION OR COMMUNICATIONS WHETHER ORAL OR WRITTEN, INCLUDING, WITHOUT LIMITATION, IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, CONFORMANCE WITH THIRD PARTY MANUFACTURER'S SPECIFICATIONS OR OTHERWISE, WHICH WOULD EXTEND BEYOND THE WARRANTIES EXPRESSLY CONTAINED HEREIN. SUBCONTRACTOR AUTHORIZES MANUFACTURER TO ASSERT AT MANUFACTURER'S EXPENSE FOR SUBCONTRACTOR'S ACCOUNT, ALL OF SUBCONTRACTOR'S RIGHTS UNDER ANY APPLICABLE THIRD PARTY MANUFACTURER'S WARRANTY, AND SUBCONTRACTOR AGREES TO COOPERATE WITH MANUFACTURER IN ASSERTING SUCH RIGHTS; PROVIDED, HOWEVER, THAT MANUFACTURER WILL DEFEND, INDEMNIFY AND HOLD SUBCONTRACTOR HARMLESS FROM AND AGAINST ANY LOSS, LIABILITY OR EXPENSE, INCLUDING REASONABLE ATTORNEY'S FEES, RESULTING FROM OR ARISING IN CONNECTION WITH ANY ACTION BY MANUFACTURER RELATING TO THE ABOVE AUTHORIZATION. THIS SECTION 7 SETS FORTH SUBCONTRACTOR'S SOLE AND EXCLUSIVE LIABILITY, AND MANUFACTURER'S SOLE AND EXCLUSIVE REMEDY, AS TO ANY FAILURE OF THE MANUFACTURER'S PRODUCTS TO MEET THE WARRANTY STANDARDS. 8. Orders; Termination.

8.1 Orders: All orders whether for Manufacturer's Products or components or inventory to be used in the manufacture of Manufacturer's Products are non-cancellable. 8.2 Termination. Either Party may terminate this Agreement and either may terminate a purchase order, effective upon written notice in any of the following events: (a) the other Party materially breaches this Agreement and such breach remains uncured for thirty (30) days following written notice of breach to the breaching Party; (b) the other Party (i) voluntarily suspends transaction of business; (ii) becomes insolvent or unable to pay any indebtedness as it matures; (iii) commences a voluntary case in bankruptcy or a voluntary petition seeking reorganization or to effect a plan or other arrangement with creditors; (iv) makes an assignment for the benefit of creditors; (v) applies for or consents to the appointment of a receiver or trustee for it or for any substantial portion of its property; (vi) makes an assignment to an agent authorized to liquidate any substantial part of its assets; (vii) has an involuntary case commenced against it with any court or other authority seeking liquidations, reorganization or a creditor's arrangement; (viii) by an order of any court or other authority, has appointed any receiver of trustee for it or for any substantial portion of its property; or (ix) has a writ or warranty of attachment or any petition seeking liquidation, reorganization or a creditor's arrangement or such order appointing a receiver or trustee is not vacated or stayed, or such writ, warranty of attachment or similar process is not vacated, released or bonded off within thirty (30) days after its entry or levy. 8.3 Party Liability Upon Termination a) Manufacturer Termination Without Cause. If the Manufacturer terminates this Agreement or cancels any purchase order without cause pursuant to Section 8.2, Subcontractor will stop all shipments and retain all inventory. Subcontractor may, at its sole discretion, assist Manufacturer in the liquidation of any inventory that is generic that does not utilize any of Subcontractor's technology. Manufacturer shall be liable for cancellation charges including the Product Costs and the costs as provided in Section 3.8. b) Manufacturer Termination With Cause. If the Manufacturer terminates this Agreement or cancels any purchase order for cause pursuant to Section 8.2 Manufacturer shall not be liable for any termination or cancellation charges but Subcontractor may, at Subcontractor's sole discretion, purchase all or part of any remaining inventory. c) Subcontractor Termination for Cause. If the Subcontractor terminates this Agreement or any purchase order for cause pursuant to Section 8.2, Manufacturer shall be liable for cancellation charges including the Product Costs and the costs as provided in Section 3.8. Subcontractor may at its sole discretion make commercially reasonable efforts to mitigate these costs by attempting to return products or components thereof to suppliers. 9. Joint Marketing. Subcontractor and Manufacturer have agreed to assist each other with marketing in other channels. When the Subcontractor helps the Manufacturer there will be a marketing fee associated with that assistance. When the Manufacturer helps the Subcontractor there will likewise be a marketing fee associated with that assistance. The Subcontractor and Manufacturer will mutually agree on the marketing fee before any assistance is provided. In some cases the marketing fee will be a percentage of the margin received by the other Party. The terms of such joint marketing agreement will be mutually agreed to by the Parties in a separate document. 10. Limitation of Liability. No Other Liability. IN NO EVENT SHALL EITHER PARTY BE LIABLE TO THE OTHER FOR ANY COVER DAMAGES (INCLUDING INTERNAL COVER DAMAGES WHICH THE PARTIES AGREE MAY NOT BE CONSIDERED DIRECT DAMAGES), OR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL OR PUNITIVE DAMAGES OF ANY KIND OR NATURE ARISING OUT OF THIS AGREEMENT OR THE SALE OF MANUFACTURER'S PRODUCTS, WHETHER SUCH LIABILITY IS ASSERTED ON THE BASIS OF CONTRACT, TORT (INCLUDING THE POSSIBILITY OF NEGLIGENCE OR STRICT LIABILITY), OR OTHERWISE, EVEN IF THE PARTY HAS BEEN WARNED OF THE POSSIBILITY OF ANY SUCH LOSS OR DAMAGE, AND EVEN IF ANY OF THE LIMITED REMEDIES IN THIS AGREEMENT





FAIL OF THEIR ESSENTIAL PURPOSE. NEITHER PARTY SHALL BE LIABLE FOR ANY DAMAGES ARISING FROM DELAY IN MANUFACTURE, SHIPMENT OR DELIVERY OF ANY MANUFACTURER'S PRODUCTS, IF SUCH DELAYS ARE DUE TO FORCE MAJEURE, AS DEFINED IN SECTION 15.2. 11. Confidentiality; Public Announcements; Non-Use; Intellectual Property Rights. 11.1 Confidentiality. Parties acknowledge that during the term of this Agreement, either Party may disclose to the other Party from time to time certain business, product pricing, financial, marketing, technical and other proprietary and sensitive information of each party. Both Parties shall use commercially reasonable efforts to keep confidential (a) the existence and terms of this Agreement and all information concerning the unit number and fees for Manufacturer's Products and inventory, and (b) any and all information concerning customers, suppliers, trade secrets, methods, processes or procedures and any other confidential, financial and business information of the other Party that is marked Confidential or the like or, if delivered verbally, confirmed in writing to be Confidential within thirty (30) days of the initial disclosure (Confidential Information) with the same standard of care as it uses for its own Confidential Information. Neither Party shall disclose Confidential Information to any third Party without the prior written consent of the other party, except that both parties agree that the other party may disclose Confidential Information to its auditors and contractors under an obligation of confidentiality, to governmental authorities having jurisdiction over such Party or as otherwise required by applicable law, provided however, in the event the Manufacturer or Subcontractor is ordered to provide Confidential Information by a lawful judicial or government order, the party who is subject to such order shall promptly inform the Party whose information is to be disclosed and shall permit the Party to defend against such order of disclosure and shall assist in such defense to the extent permitted by law. In no other circumstances may the Manufacturer or Subcontractor disclose information without the consultation and prior written consent of the non-disclosing Party. Confidential Information of either Party hereto shall not include information which (i) is in the public domain, (ii) is previously known or independently developed by the receiving Party, (iii) is acquired by the receiving Party from any third party having a right to disclose such information or (iv) the receiving party is obligated to produce under a court or governmental order; provided, the disclosing Party complies with the notice requirements of the previous paragraph with respect the information subject to such court or governmental order. The Parties acknowledge that a breach by either Party of this Section 11 will give rise to irreparable injury to the other, inadequately compensable in damages. Accordingly, the Parties hereby consent to allow the other Party to seek injunctive relief against the breach or threatened breach of the undertakings of the Parties contained in this Section 11. The Parties further agree that such an order so enjoining a Party may be issued pending final determination thereof, without the requirement to post bond. 11.2 Public Announcements. Each Party reserves the right to publish press releases and public announcements (collectively, the Publications) pertaining to this Agreement; provided, however, no Publications will contain any Confidential Information of a Party without such Party's prior written consent. The publishing Party shall indemnify and hold the non-publishing Party its, officers, agents, shareholders, and employees harmless against any and all claims, demands, damages, liabilities and costs which directly or indirectly result from, or arise in connection with, any negligent act or omission of the disclosing Party, its agents, or employees, pertaining to such disclosing Party's Publications under this Agreement. 11.3 Non-Use. Each Party to this Agreement acknowledges and agrees that at any time during the Term of this Agreement and at all times following the termination of this Agreement, neither Party may use any Confidential Information, Inventions and Intellectual Property (as these terms are defined in Section 11.3 below) of the other Party for any purpose other than in conjunction with its obligations under this Agreement. The Parties further agree that neither Party may analyze, or reverse engineer any samples, software or hardware provided by the other Party to determine composition, method of manufacture, or construction. 11.4 Intellectual Property Rights. Except as otherwise expressly provided in this Section 11,4, all inventions, discoveries, and trade secrets whether or not patentable, that are made by Subcontractor or Manufacturer, either alone or with others, in the course of its performance of its obligations under this Agreement (collectively, Inventions) will become the exclusive property of Subcontractor. In the event this Agreement terminates for any reason or no reason, all licenses of Subcontractor's patents, trademarks, software, trade secrets or other intellectual property (collectively the Intellectual Property) of Subcontractor, granted expressly or otherwise to Manufacturer under the terms of this Agreement or any other Agreement between Subcontractor and Manufacturer shall immediately terminate and Manufacturer must immediately cease use of all of Subcontractor's Intellectual Property. 12. Manufacturer's Indemnity. Manufacturer shall indemnify, defend and hold Subcontractor and its affiliates (Subcontractor Indemnities) harmless from and against any and all loss, liability or expense, including reasonable attorneys' fees, resulting from or arising in connection with any claim or suit by any third party against the Subcontractor Indemnities (i) alleging infringement or dilution of any copyright, trademark, trade name, trade secret, patent or other third party proprietary rights, relating to the design, manufacture, sale, normal use or normal disposition of any Manufacturer's Products built to the specification of Manufacturer, (ii) alleging any failure of any Manufacturer's Product (or any Manufacturer's Product components contained therein) sold by Subcontractor hereunder to comply with any safety standards or any environmental regulations, or (iii) alleging loss, damages, bodily injury, sickness, disease, or death, or injury to property which is caused by (1) the negligence or intentional acts of Manufacturer, its agents, employees or subcontractors, or (2) a defect in Manufacturer Specifications or Manufacturer specified materials, components or design of the Manufacturer's Products or caused by Manufacturer specified suppliers; provided however, that Subcontractor shall have the right, at its option, to participate in the defense of any such claim or suit,





without relieving Manufacturer of any obligations hereunder. 13. Ownership of Tooling and Testing Equipment. All tooling and testing equipment used in connection with this Agreement shall be owned by Subcontractor.

14. Regulatory Compliance and Record Keeping.

14.1 Approvals. Manufacturer shall be registered as the manufacturer of Manufacturer's Products and shall obtain such approvals from the United States Food and Drug Administration (the FDA) and other regulatory bodies, public or private as may be required to manufacture and sell the products in the United States or internationally. Both Manufacturer and Subcontractor shall be responsible for complying with all federal, state and local laws, rules, regulations, guidelines and the like in the United States and in other countries as they may pertain to the Manufacturer's Products and to the obligations on the Parties to perform under this Agreement, including, without limitation, requirements in the United States with respect to registration of establishment, listing of medical devices, reporting of deaths, serious injuries and certain malfunctions under 21 CFR Medical Device Regulations and the potential therefore, tracking of medical devices, recalls, safety alerts and process controls. In no event shall either Party assume any risk arising out of the other Party's failure to comply with such laws, rules, regulations, guidelines and the like, and each Party shall cooperate with the other in all respects to facilitate and promote strict compliance with the provisions of this Section 14.

14.2 Regulatory Inspection and Revision of Specifications. Following inspections by applicable regulatory authorities, including, without limitation, the FDA, Subcontractor shall do such actions or cause such actions to be done that are necessary, advisable or appropriate so that Subcontractor remains in good standing with any such regulatory authorities. Prior to undertaking any action pursuant to this section, Subcontractor shall notify Manufacturer of the inspection and disclose to Manufacturer the regulatory authorities' findings and related results of such inspection (the Findings) pertaining to the business with Manufacturer. Subcontractor shall also provide full disclosure to Manufacturer with respect to any action undertaken or proposed to be undertaken pursuant to this Section prior to acting. Subcontractor shall keep correct and complete records and books covering the manufacture of the Manufacturer's Products and other documents relating to this Agreement. Each of the Parties will immediately notify the other of any complaints, adverse events, deaths or serious injuries relating to Manufacturer's Products that are manufactured by Subcontractor. All complaints, adverse events, deaths or serious injuries pertaining to Manufacturer's Products will be reported to Subcontractor's Quality Assurance departments in accordance with the requirements established in Subcontractor's and Manufacturer's Complaints Handling and Reporting procedures. All complaint related Manufacturer's Products returned to Manufacturer will be forwarded to Subcontractor for complaint handling and failure investigation. Subcontractor agrees to provide Manufacturer, at Manufacturer's expense and reasonable request and during ordinary business hours, access to, and copies of, such records, books and all other documents and materials in the possession and under the control of Subcontractor relating to or pertaining to the subject matter of this Agreement; including, but not limited to, the following:

a) Subcontractor will provide Manufacturer a schedule of all audits of Subcontractors for materials used in the manufacture of Manufacturer's Products upon request. The schedule will be provided in accordance with the requirements established in Subcontractor's Auditing procedure. Reports on all material Subcontractors for the Manufacturer's Products will be made available to Manufacturer upon request.

b) Upon reasonable notice, Manufacturer may review at any time routine reports relating to all nonconforming materials identified by Subcontractor during the manufacture or inspection of the Manufacturer's Products.

Subcontractor shall maintain quality systems in compliance with ISO 9001 (the 2000 or current version) and the Quality System Requirements of the FDA. 14.3 Change Notification. Subcontractor will notify Manufacturer and obtain approval prior to implementing changes that may require amendments to the Device Master Record, manufacturing process changes or material changes relating to the manufacture and distribution of Manufacturer's Products. Manufacturer will notify Subcontractor of all changes to the Device Master Record, manufacturing process changes or material changes relating to the manufacture of Manufacturer's Products manufactured by Subcontractor. Manufacturer will provide appropriate documentation to Subcontractor to effect any changes to the Device Master Record, manufacturing process or changes in materials. 15. General Provisions.

15.1 Notice. Notice shall be deemed effective and delivered three days after mailing if sent certified mail, return receipt requested, or when received if sent by electronic mail (e-mail), telecopy, prepaid courier, express mail or personal delivery to the intended recipient thereof at the address shown on the first page hereof with confirmation of delivery, or to such other address as either Party may specify in a written notice to the other Party pursuant hereto.





15.2 Force Majeure. Except as otherwise provided herein, neither Party shall be liable to the other for its failure to perform any of its obligations hereunder during any period in which performance is delayed by circumstances beyond its reasonable control, including, without limitation, an act of God, war, civil disturbance, court order, labor dispute, third party nonperformance, acts of third parties, or failures, fluctuations or non-availability of materials, components, electrical power, heat, light, air conditioning, computing or information systems or telecommunications (force majeure), provided that the Party experiencing such delay promptly notifies the other Party of the delay and the cause thereof. The happening of any contingency beyond Subcontractor's reasonable control, including delays caused by Manufacturer or suppliers, shall not constitute cause for cancellation of Manufacturer's order, but shall extend Subcontractor's time to ship goods for a period equal to the duration of such contingency.

15.3 Relationship of Parties. Subcontractor, in providing Manufacturer's Products hereunder, is acting as an independent contractor and does not undertake by this Agreement or otherwise to perform any obligation of Manufacturer, or to assume liability for Manufacturer's business or operations. Subcontractor has the sole right and obligation to supervise, manage, contract, direct, procure, perform, or cause to be performed, all work to be performed by Subcontractor hereunder.

15.4 Right of Subcontractor to Sell Products to Others. Manufacturer understands and agrees that Subcontractor may itself use, manufacture or sell similar products as provided to Manufacturer hereunder to third parties and affiliates, some of whom may be competitors of Manufacturer, so long as: (a) Subcontractor does not use or disclose any Confidential Information of Manufacturer, (b) Subcontractor and third party do not infringe any of Manufacturer's patents or other intellectual property rights.

15.5 No Third Party Beneficiaries. The Parties agree that this Agreement is for the benefit of the Parties hereto only and is not intended to confer any legal rights or benefits on any third party, and that there are no third party beneficiaries to this Agreement or any part or specific provision of this Agreement.

15.6 Attorneys' Fees. The prevailing Party in any legal proceedings brought by or against the other Party to enforce any provision of this Agreement shall be entitled to recover against the non-prevailing Party the reasonable attorneys' fees, court costs and other expenses incurred by the prevailing Party. 15.7 Assignment; Change of Control. Neither Party may assign or transfer this Agreement by operation of law or otherwise. Any assignment made by either Party in contravention of this Section 15.7 shall be null and void for all purposes. In the event of a Change of Control (as defined below) this Agreement shall immediately terminate. A Change of Control shall occur with respect to the Manufacturer, unless Subcontractor shall have expressly consented to such Change of Control in writing. A Change of Control shall mean any event or circumstance as a result of which (i) any Person or group (as such terms are defined in Sections 13(d) and 14(d) of The Securities Exchange Act of 1934 (the Exchange Act), as in effect on the date hereof), other than the Subcontractor, is or becomes the beneficial owner (as defined in Rules 13(d)-3 and 13(d)-5 under the Exchange Act), directly or indirectly, of 50% or more on a fully diluted basis of the then outstanding voting equity interest of the Company, (ii) the board of directors of the Manufacturer shall cease to consist of a majority of the Manufacturer's board of directors on the date hereof (or directors appointed by a majority of the board of directors in effect immediately prior to such appointment) or (iii) the Manufacturer or any of its affiliates merges or consolidates with, or sells all or substantially all of its assets to, any other person or entity; 15.8 Amendment. This Agreement may be amended only by written amendment duly signed by authorized representatives of both Parties.

15.9 Non-Solicitation of Employees. During the term hereof and for a period of five (5) years thereafter, each Party agrees not to, either directly or indirectly, for itself or on behalf of any other person, firm, partnership, corporation or other entity hire, solicit, contract for, attempt to solicit, or cause to be solicited, the employment or services of any current or previous employee of the other Party (unless a period of sixty months has elapsed from the last date that such employee was employed by such party) without the prior written consent of such other Party. Each Party agrees that in the event it violates the provisions of this Section 15.9, it will pay to the other Party as liquidated damages, and not as a penalty, an amount equal to one hundred times (100 X) of any such employee's then-current base annual salary. 15.10 Severability; Validity. If any provision of this Agreement is held invalid or unenforceable under applicable law, the parties agree to renegotiate such provision(s) in good faith, in order to maintain or achieve the economic position enjoyed by each Party as close as possible to that under the provision(s) rendered unenforceable. In the event that the Parties cannot reach a mutually agreeable and enforceable replacement for such provision(s), then (i) such provisions shall be excluded from this Agreement, (ii) the balance of the Agreement shall be interpreted as if such provision(s) were so excluded, (iii) the balance of the Agreement shall be enforceable in accordance with its terms, and (iv) the parties will revise the Agreement to effect the intent of such excluded provisions. 15.11 Waiver. Any waiver of any kind by a Party of a breach of this Agreement must be in writing, shall be effective only to the extent set forth in such writing and shall not operate or be construed as a waiver of any subsequent breach. Any delay or omission in exercising any right, power or remedy pursuant to a breach or default by a Party shall not impair any right, power or remedy which either Party may have with respect to a future breach or default.

15.12 Dispute Resolution. 15.12.1 Obligation to Negotiate. Any dispute arising out of or relating to this Agreement shall be resolved exclusively in accordance with the procedures specified in this Section 15.12. The Parties shall attempt in good faith to resolve any





dispute arising out of or relating to this Agreement by negotiation between a committee composed of four (4) members (two (2) from each Party) mutually agreed upon from the Subcontractor and Manufacturer boards of directors. Any Party may give the other Party written notice of any dispute not resolved in the normal course of business. Such notice shall include (a) a statement of that Party's position and a summary of arguments supporting that position, and (b) the name and title of the executive who will be representing that Party and of any other person who will accompany the executive in the negotiations. Within fifteen (15) days after delivery of the notice, the receiving Party shall respond with (a) a statement of that Party's position and a summary of arguments supporting that position, and (b) the name and title of the executive who will represent that Party and of any other person who will accompany the executive in the negotiations. Within thirty (30) days after delivery of the initial notice, the executives of both Parties shall meet at a mutually acceptable time and place and thereafter as often as they reasonably deem necessary to attempt to resolve the dispute. All reasonable requests for information made by one Party to the other will be honored. All negotiations pursuant to this clause are confidential and shall be treated as compromise and settlement negotiations for purposes of applicable rules of evidence. 15.12.2 Mediation. If the dispute has not been resolved by the negotiation process specified in Section 15.12.1 within forty-five (45) days following the initial notice, the Parties may endeavor to settle the dispute by mediation under the then current CPR Mediation Procedure published by the CPR Institute for Dispute Resolution (NYC). Unless otherwise agreed, the Parties will select a mediator from the CPR Panels of Distinguished Neutrals. 15.12.3 Choice of Law; Venue. If any dispute has not been resolved by a non-binding procedure as provided herein, within one-hundred twenty (120) days of the initiation of such procedure the complaining Party may seek such legal or equitable relief as may be appropriate in the federal or state courts located in Maricopa County, Arizona. The Parties agree that this Agreement shall be governed by and construed in accordance with the laws of the State of Arizona without regard to conflicts of law provisions thereof or any other applicable law and that exclusive venue shall be in the federal or state courts located in Maricopa County, Arizona. Nothing stated herein is intended to limit either Party's right to seek emergency, temporary or permanent injunctive relief and both Parties expressly agree that either Party will be entitled to such relief to prevent actual or threatened violation of the confidentiality provisions in Section 11 herein. If there is a dispute or legal action regarding this agreement, the prevailing Party shall be entitled to reasonable attorney's fees and costs. 15.13 Binding Effect; Recitals. This Agreement shall be binding on and inure to the benefit of the Parties and their respective successors and assigns. The recitals to this Agreement are incorporated into and shall constitute a part of this Agreement.

15.14 Survival. The rights, limitations, obligations and duties under Sections 7, 10, 11, 12, 14 and 15 shall survive the expiration or termination of this Agreement. 15.15 Entire Agreement. This Agreement and the attachments attached hereto contain the entire agreement of the Parties with respect to the subject matter of this Agreement, and supersede all prior negotiations, agreements and understandings with respect thereto. Signature Page to Follow





IN WITNESS WHEREFORE, the Parties have caused this Agreement to be executed by their duly authorized representatives as set forth below: ZOUNDS HEARING, INC. Date: ________________________ By:______________________________ Name: Samuel L. Thomasson Title: President & Chief Executive Officer Address: 6825 W. Galveston Street, Suite 9 Chandler, AZ 85226 Fax: _____________________________ Email: ____________________________ INNERSCOPE HEARING TECHNOLOGIES, INC. Date: ________________________ By:________________________________ Name: Matthew Moore Title: CEO Address: 2151 Professional Drive 2nd Floor Roseville, CA. 95616 Fax: (916) 218-4101 Email: matthew@innd.com 
Question: Highlight the parts (if any) of this contract related to Warranty Duration that should be reviewed by a lawyer. Details: What is the duration of any  warranty against defects or errors in technology, products, or services  provided under the contract?

Output: 15838


Input: Consider Input: Exhibit 4.44 THIS LICENSE AND RESELLER AGREEMENT dated as of the October 30, 2018 is made BETWEEN: EHAVE, INC., a company incorporated under the laws of the Province of Ontario, Canada (Ehave); - and - COMPANION HEALTHCARE TECHNOLOGIES CORP, a company incorporated under the laws of the Province of Ontario (CHT) RECITALS: A. Ehave has developed a software platform that provides an end-to-end patient management solution to healthcare professionals and provides that platform to users as a service. B. CHT has developed a business model to bring a similar service that Ehave provides using the Ehave Platform for the domain of the animal market including companion animals (i.e. pets). C. The Parties desire to enter into this Agreement to enable CHT to pursue its business model whereby CHT will license and provide services in relation to companion and other animals using the Ehave Companion Solution under the terms and conditions contained herein. NOW THEREFORE, in consideration of the premises and the mutual agreements hereinafter set out herein and of other consideration (the receipt and sufficiency of which are acknowledged by each Party), the Parties covenant and agree as follows: 1. INTERPRETATION (a) Definitions In this Agreement and the schedules annexed hereto, the following terms shall have the respective meanings indicated below: Acceptance Criteria has the meaning ascribed to it in Section 3(d). Acceptance Period has the meaning ascribed to it in Section 3(d). Acceptance Procedures has the meaning ascribed to it in Section 3(d). Agreement means this license and reseller agreement and all Schedules, Appendixes and Exhibits attached hereto. Applicable Laws means any and all (i) laws, statutes, rules, regulations, by laws, codes, treaties, constitutions and ordinances, including Privacy Legislation (Laws), (ii) order, directive, judgment, decree, award or writ of any court (including a court of equity), arbitrator or arbitration panel, or any Governmental Authority or other body exercising adjudicative, regulatory, judicial or quasi-judicial powers, including any stock exchange (Orders), and (iii) policies, guidelines, standards, requirements, notices and protocols of any Governmental Authority (Policies); which are applicable to or govern CHT, Ehave or the transactions contemplated by this Agreement.

Source: EHAVE, INC., 20-F, 5/15/2019





Authentication ID means a security mechanism by which an Authorized User identifies herself or himself to the Ehave Companion Solution and gains access thereto, which security mechanism may include user identification, passwords, digital certificates or any other similar process mechanism for authentication and recognition as determined by Ehave from time to time. Authorized User means an individual who an End User has authorized to access and use CHT's services, which includes the use of the Ehave Companion Solution. Business Day means any calendar day except for Saturday or Sunday or any statutory holiday observed in the Province of Ontario. CHT Developments has the meaning ascribed to it in Section 4(a). CHT Indemnified Parties has the meaning ascribed to it on Section 16(a). CHT Marks means the names, trademarks, trade names, service marks, designs and logos of CHT. Claim has the meaning ascribed to it in Section 16(a). Competitive Transaction has the meaning ascribed to it in Section 2(d). Confidential Information means this Agreement, the Ehave Companion Solution, End User Data and all ideas, designs, business models, databases, drawings, documents, diagrams, formulas, test data, marketing, financial or personnel data, sales information, customer or supplier information, including information provided by such customers or suppliers, or any other information already furnished and to be furnished or made available by one Party to the other, whether in oral, written, graphic or electronic form including any such information exchanged during informational sessions designated as confidential, including, without limitation, information concerning a Party's actual and potential customers and other Intellectual Property Rights of such Party, provided, however, that Confidential Information shall not include any data or information: (i) that, at the time of disclosure, is in or, after disclosure, becomes part of the public domain, through no act or failure on the part of the receiving Party, whether through breach of this Agreement or otherwise; (ii) that, prior to disclosure by the disclosing Party, was already in the possession of the receiving Party, as evidenced by written records kept by the receiving Party in the ordinary course of its business, or as evidenced by proof of actual prior use by the receiving Party; (iii) independently developed by the receiving Party, by Persons having no direct or indirect access to the disclosing Party's Confidential Information provided that the receiving Party provides clear and convincing evidence of such independent development; (iv) which, subsequent to disclosure, is obtained from a third Person: (A) who is lawfully in possession of such information; (B) who is not in violation of any contractual, legal, or fiduciary obligation to either Party, as applicable, with respect to such information; and (C) who does not prohibit either Party from disclosing such information to others; or (v) is further disclosed with the prior written consent of the disclosing Party, but only to the extent of such consent. Effective Date means the date first written above. Ehave Companion Solution means the Ehave Platform, as modified, adapted and customized, as provided herein, the specifications of which are set out in Schedule 1.

2.

Source: EHAVE, INC., 20-F, 5/15/2019





Ehave Platform means the Software, Ehave Server and such devices and peripherals physically located with the Ehave Server, including all computer hardware, software, network elements, and electrical and telecommunications infrastructure located behind the Point of Access. Ehave Server means that computer server located at Ehave's premises, or a third party provider of hosting and/or network services, that houses the Software. End User means CHT's customers who have entered into a subscription agreement with CHT for CHT services, which services include the use of the Ehave Companion Solution. End User Data means collectively any data, files, documentation or other information (including personal information) that an End User or any of its Authorized Users may: (i) upload to the Ehave Companion Solution; and/or (ii) have processed through the use of the Ehave Companion Solution, and includes any data or output resulting from or derived from such use. Escrow Agent has the meaning ascribed thereto in Section 12(a). Escrow Agreement has the meaning ascribed thereto in Section 12(a). Field of Use means indications and outcomes related to any companion and other animals. Governmental Authority means any domestic, foreign or supranational government, whether federal, provincial, state, territorial or municipal; and any governmental agency, ministry, department, tribunal, commission, bureau, board or other instrumentality, including international institutions, exercising or purporting to exercise legislative, judicial, regulatory or administrative functions of, or pertaining to, government. Implementation Plan has the meaning ascribed to it in Section 3(a). Intellectual Property means any property, tangible or intangible, that may be subject to Intellectual Property Rights, including without limitation, ideas, formulae, algorithms, concepts, techniques, processes, procedures, approaches, methodologies, plans, systems, research, information, documentation, data, data compilations, specifications, requirements, designs, diagrams, programs, inventions, technologies, software (including its source code), tools, products knowledge, know-how, including without limitation, trade secrets, and other materials or things. Intellectual Property Rights means (a) any and all proprietary rights anywhere in the world provided under (i) patent law; (ii) copyright law, including moral rights; (iii) trademark law; (iv) design patent or industrial design law; (v) semiconductor chip or mask work law; (vi) trade secret law; (vii) privacy law; or (viii) any other statutory provision or common law principle applicable to this Agreement which may provide a right in either (A) Intellectual Property; or (B) the expression or use of Intellectual Property; and (b) any and all applications, registrations, licenses, sub-licenses, franchises, agreements or any other evidence of a right in any of the foregoing. Objectionable Content means content that infringes any Applicable Laws or third party rights, and content which is obscene, indecent, pornographic, seditious, defamatory, threatening, liable to incite racial hatred, menacing, blasphemous, misleading, deceptive or in breach of any person's Intellectual Property Rights. Party means either Ehave or CHT; and Parties means both of them. Person means any individual, estate, sole proprietorship, firm, partnership, unincorporated association, unincorporated syndicate, unincorporated organization, limited liability company, corporation, body corporate, trustee, trust, Governmental Authority or other entity or organization and includes any successor to any of the foregoing.

3.

Source: EHAVE, INC., 20-F, 5/15/2019





Point of Access means Ehave's, or its subcontractor's, border router, which is used to establish connectivity from the Ehave Platform to Ehave's, or its subcontractor's, Internet provider, or the public Internet. Royalties means the fees, charges and other amounts to be paid by CHT to Ehave for the rights granted hereunder and which amounts are set out in Schedule 6. Security Requirements means those safeguards and controls set out in Schedule 5. Software means Ehave's proprietary patient and data management software and any related documentation, as modified for use in the animal (including companion animal) and veterinary industry. Source Code means the human-readable form of a computer instruction, including, but not limited to, related system documentation, flow charts, all comments and any procedural code and a description of the procedure for generating object code, all of a level sufficient to enable a programmer reasonably fluent in the programming language in which the Software was written to understand, build, operate, support, maintain and develop modifications, upgrades, updates, adaptations, enhancements, new versions, and other derivative works and improvements of, and to develop computer programs compatible with, the Software. Specifications has the meaning ascribed to it in Section 3(a).Subscription Agreement has the meaning ascribed to it in Section 5(b). Term has the meaning ascribed to it in Section 9. Territory means any jurisdiction in the World where the use of the Ehave Companion Solution for the intended purpose herein is permitted under Applicable Law. Transition out Period has the meaning ascribed to it in Section 10(f). Transition-out Services has the meaning ascribed to it in Section 10(f). Virus means a piece of code usually (but not necessarily) disguised as something else that causes some unexpected and, for the victim, usually undesirable, event and which is designed so that it may automatically spread to other computer users; the term 'Virus' will also be deemed to include worms, cancelbots, trojan horses, harmful contaminants (whether self-replicating or not) and nuisance causing or otherwise harmful applets. (b) Headings; Extended Meanings The division of this Agreement into articles, sections, schedules and other subdivisions, and the inclusion of headings are for convenience of reference only and shall not affect the construction or interpretation of this Agreement. The headings in the Agreement are not intended to be full or precise descriptions of the text to which they refer. Unless something in the subject matter or context is inconsistent therewith, references herein to Articles and Sections are to Articles and Sections of this Agreement. The word including or include(s) means including without limitation or include(s) without limitation. (c) Currency Unless otherwise specified, all references to monetary amounts, including the symbol $, are in respect of Canadian currency.

4.

Source: EHAVE, INC., 20-F, 5/15/2019





(d) Exhibits and Schedules The following Schedules are a part of and are integral to this Agreement: Schedule 1 - Ehave Companion Solution Specifications Schedule 2 - Development and Implementation Plan Schedule 3 - Support Procedures Schedule 4 - Service Level Commitments Schedule 5 - Security Requirements Schedule 6 - Royalties and Early Termination Fee Schedule 7 - Source Code Escrow (e) Entire Agreement This Agreement, together with any other documents to be delivered pursuant hereto, constitutes the entire agreement between the Parties pertaining to the subject matter hereof and supersedes all prior agreements, negotiations, discussions and understandings, written or oral, between the Parties. Except as expressly provided in this Agreement, there are no representations, warranties, conditions other agreements or acknowledgements, whether direct or collateral, express or implied, that form part of or affect this Agreement. The execution of this Agreement has not been induced by, nor do either of the Parties rely upon or regard as material, any representations, warranties, conditions, other agreements or acknowledgements not expressly made in this Agreement or in the other documents to be delivered pursuant hereto. (f) Governing Law: This Agreement shall be governed by, and construed and enforced in accordance with, the laws in force in the Province of Ontario (excluding any conflict of laws rule or principle which might refer such construction to the laws of another jurisdiction). The Parties hereto agree to submit to the exclusive jurisdiction of the courts of the Province of Ontario and waive any objection relating to improper venue or forum non conveniens to the conduct of any proceeding in any such court. (g) Severability: In the event that any provision (or any portion of a provision) of this Agreement shall for any reason be held by a court of competent jurisdiction to be invalid, illegal, or unenforceable for any reason, such invalidity, illegality or unenforceability shall not affect any other provision hereof and this Agreement shall be construed as if such invalid, illegal or unenforceable provision (or portion of a provision) had never been contained herein in regards to that particular jurisdiction. 2. APPOINTMENT AND LICENSE GRANT (a) Exclusive Appointment Ehave hereby appoints CHT, and CHT hereby accepts the appointment, to act as Ehave's reseller of the use of the Ehave Companion Solution within the Field of Use in the Territory for the duration of the Term solely in accordance with the terms and conditions of this Agreement. Subject to Section 2(e), the foregoing appointment is exclusive such that Ehave shall not appoint any other Person to, nor may Ehave itself, sell or resell the use of the Ehave Companion Solution within the Field of Use anywhere in the Territory.

5.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Grant by Ehave Subject to the terms and conditions of this Agreement commencing as of the Effective Date and for the duration of the Term and any Transition-out Period, Ehave hereby grants to CHT a non-transferable (except as permitted under Section 20(f)), right to: (i) sub-license the use of the Ehave Companion Solution within the Field of Use in the Territory to End Users and their respective Authorized Users, including in operation or by interfacing with other software, hardware, systems, networks and services, in accordance with and subject to the provisions of CHT's Subscription Agreement; and (ii) use the Ehave Companion Solution to support its licensed End Users. Subject to Section 2(e), the grant set out in Clause 2(b)(i) is exclusive such that Ehave shall not license any other Person to, nor may Ehave itself, license, sub-license the use of, or provide services similar to, the Ehave Companion Solution within the Field of Use anywhere in the Territory. (c) Restrictions on Use Any rights not granted herein are strictly reserved by Ehave. CHT shall not, and shall not permit others to, reverse engineer, decompile, disassemble or translate any software used by Ehave to provide the Ehave Companion Solution, or otherwise attempt to view, display or print such software, including its Source Code, except as permitted herein. (d) Prohibition on Competitive Solutions For so long as the appointment set out in Section 2(a) is exclusive, CHT shall not enter into an agreement (a Competitive Transaction) with any other Person related to the license, sub-license, sale, resale or provide service, solutions, goods or products, that are substantially similar to or competitive with the Ehave Companion Solution. For clarity, a Competitive Transaction shall not include an agreement for use, integration or interfacing, or co-marketing, of the Ehave Companion Solution with other services, solutions, devices, goods or products, where such other services, solutions, devices, goods or products do not contain the same or similar functionality of the Ehave Companion Solution, but provides for a complementary solution. (e) Conversion to Non-Exclusive Notwithstanding anything to the contrary contained herein, the exclusive appointment and license set out in Sections 2(a) and 2(b) shall become non-exclusive if: (i) at any time during the Term hereof, CHT breaches Section 2(d) as determined by arbitration in accordance with Section 19(c) or by a final non-appealable judgment of a court of competent jurisdiction; or (ii) at any time after November 1, 2010 CHT fails to achieve annual revenues of $500,000. (f) No Franchise Agreement The Parties to this Agreement are independent contractors and nothing in this Agreement shall be deemed or constructed as creating a joint venture, partnership, agency relationship, or franchise between Ehave and CHT. Neither Party, by virtue of this Agreement, will have any right, power or authority to act or create an obligation, express or implied, on behalf of the other Party. Each Party assumes responsibility for the actions of their personnel under this Agreement and will be solely responsible for their supervision, daily direction and control, wage rates, withholding income taxes, Canada Pension Plan contributions, employment insurance premiums, disability benefits, or the manner and means through which the work under this Agreement will be accomplished. Except as provided otherwise in this Agreement, CHT has the sole discretion to determine CHT's methods of operation, CHT's accounting practices, the types and amounts of insurance CHT carries, CHT's personnel practices, CHT's advertising and promotion, CHT's customers and CHT's service areas and methods. The relationship created hereby between the parties is solely that of supplier and reseller, and licensor and licensee.

6.

Source: EHAVE, INC., 20-F, 5/15/2019





3. DEVELOPMENT AND IMPLEMENTATION OF THE COMPANION SOLUTION (a) Specifications and Implementation Attached hereto as Schedule 1 are the business requirements and technical specifications of the Ehave Companion Solution (the Specifications). Attached hereto as Schedule 2 is the development and implementation plan (the Implementation Plan), which sets out the procedures and obligations of each of the Parties and the key milestones and timelines in relation to the development and implementation of the Ehave Companion Solution. The Parties acknowledge that at the time of execution of this Agreement that the Specifications and Implementation Plan may not have been fully developed, but that the creation of the Specifications and development of the detailed Implementation Plan will be the first step in respect of the development and implementation of the Ehave Companion Solution, in which case, once approved by the Parties in writing, the Specifications and Implementation Plan so developed will be attached hereto and shall replace Schedules 1 and 2 respectively. Once finalized the Specifications and Implementation Plan may not be changed or modified by either Party, except in accordance with the procedures set out in Section 3(c). (b) Obligations Each of Ehave and CHT shall perform, at their own expense (or as otherwise set out in Schedule 6), their respective obligations and responsibilities set out in the Implementation Plan as necessary to accomplish the development and implementation of the Ehave Companion Solution in accordance with the milestones and timelines set out therein. CHT acknowledges that the development and implementation of the Ehave Companion Solution requires decisions and input from CHT and for CHT to perform its obligations thereunder in a timely manner. In the event that CHT delays in providing such decisions, input or performance of its obligations, the development and implementation of the Ehave Companion Solution shall be correspondingly delayed. Subject to the foregoing, Ehave acknowledges that time is of the essence with respect to its obligations hereunder and that prompt and timely performance of all such obligations, including all development and implementation dates, timetables, project milestones and other requirements in this Agreement is strictly required. Once the implementation of the Ehave Companion Solution is completed, Ehave shall notify CHT of such completion and that the Ehave Companion Solution is ready for testing in accordance with Section 3(d).

7.

Source: EHAVE, INC., 20-F, 5/15/2019





(c) Change Control Process Either Party may request additions, deletions or amendments in respect of the development and implementation of the Ehave Companion Solution (Change). Changes shall be requested in writing signed by an authorized representative of the Party requesting the Change (Change Request). Ehave shall have no obligation to perform, and CHT shall have no obligation to pay for, services related to any proposed modification or change unless both Parties have agreed to the modifications or changes in writing in accordance with the procedures set forth herein. The Change Request shall include a reasonably detailed description of the scope and nature of the requested Change. If CHT desires a Change, Ehave shall evaluate the feasibility of such change as it relates to the proposed Field of Use. As soon as reasonably possible after receipt of CHT's request, Ehave agrees to provide CHT with a written estimate of the cost, if any, of and the timing to implement the requested Changes as well as any additional terms and conditions related to such Changes. The costs, if any, associated with the development of such estimate shall be borne by CHT. Upon CHT's approval in writing of the cost estimate and any additional terms and conditions related to such Changes, including delivery dates and payment terms provided by Ehave, the Parties shall revise the Specifications and Implementation Plan and shall replace the Specifications and Implementation Plan attached hereto as Schedules 1 and 2, and Ehave shall develop and implement the Change as so agreed. Changes shall be subject to acceptance testing by CHT prior to being deployed into production in accordance with procedures described in Section 3(d) or as otherwise agreed by the parties in writing. Ehave shall not refuse to accept a CHT Change request unless it is unable to make the Change requested using commercially reasonable efforts, in which event Ehave will provide an explanation to CHT; or Ehave and CHT fail to agree on the terms and conditions related to the performance of such Change, including the costs, if any. If a mutually acceptable resolution is not reached in respect of a CHT Change request, the Parties may submit the issue to mediation pursuant to Section 19(b). (d) Acceptance The criteria (Acceptance Criteria) which the Ehave Companion Solution is to meet and the procedures by which such criteria are to be tested (Acceptance Procedures) shall be set out in the Implementation Plan and shall follow the requirements set out in this Section 3(d). Once notified by Ehave that the Ehave Companion Solution is ready for acceptance testing, CHT shall perform the tests as set out in the Acceptance Procedures. Unless otherwise set out in the Acceptance Procedures, CHT shall have ten (10) Business Days to perform the acceptance tests as set out in the Acceptance Procedures and to provide Ehave written notice of acceptance or non-acceptance of the Ehave Companion Solution (the Acceptance Period). CHT shall not refuse to accept the Ehave Companion Solution unless all or one or more portions of the Solution fail to perform, in any material respect, in accordance with the Acceptance Criteria. Any notice of non- acceptance shall describe the material failure of the Ehave Companion Solution in reasonable detail and CHT shall provide Ehave with reasonably detailed documentation and explanations, together with underlying data, to substantiate the failure and to reasonably assist Ehave in its efforts to diagnose and correct the failure. If CHT gives notice to Ehave of non-acceptance of the Ehave Companion Solution then Ehave shall investigate the reported failure in good faith and correct same, and if the engagement is on a fixed fee basis at no additional cost to CHT, within fifteen (15) Business Days unless an extension is granted by CHT. If, within such fifteen (15) Business day period (or extended period, as applicable), Ehave corrects the failure, then Ehave shall give written notice to CHT certifying that the failure has been corrected, and another Acceptance Period of the same duration as the initial Acceptance Period shall begin and shall be governed by the provisions of this Section 3(d) upon delivery of the corrected Ehave Companion Solution to CHT. If the Acceptance Procedures were conducted three (3) times in respect of the initial implementation of the Ehave Companion Solution, and the eHAve Companion Solution failed to pass the Acceptance Criteria on the third (3rd) try, then, at the discretion of either Party, Ehave may continue to fix the problem, or terminate this Agreement in which case, CHT shall promptly return to Ehave all copies of the Ehave Companion Solution, including the Specifications and any other items delivered to CHT by Ehave thereunder and Ehave shall promptly refund to CHT any monies paid by CHT in respect of the initial development and implementation of the Ehave Companion Solution. If the Acceptance Procedures were conducted three (3) times in respect of a Change, and the Change failed to pass the Acceptance Criteria on the third (3rd) try, then, at the discretion of CHT, Ehave may continue to fix the problem, or terminate the performance of the development of the Change, in which case CHT shall promptly return to Ehave all copies of the Change, including the Specifications thereto and Ehave shall promptly refund to CHT any monies paid by CHT in respect of the development and implementation of the Change.

8.

Source: EHAVE, INC., 20-F, 5/15/2019





(e) Deployment Once CHT provides Ehave written notice of acceptance, Ehave will deploy the Ehave Companion Solution or Change, as applicable, by putting the Ehave Companion Solution or Change into production in accordance with, and within the timelines set out, in the Implementation Plan or Change Request, as the case may be. (f) Branding The Ehave Companion Solution may, in the sole discretion of CHT, be branded, marketed, advertised, promoted and sublicensed under CHT Marks. For such purpose, CHT hereby grants to Ehave a non-exclusive, royalty-free, revocable, limited license during the Term and Transition-out Period and within the Territory to use, reproduce, publish and display the CHT Marks solely in connection with the operation of the Ehave Companion Solution for and on behalf of CHT and End Users. Ehave agrees that its use of any CHT Marks will comply with CHT's branding guidelines to the extent made available by CHT to Ehave from time to time and will enure to the benefit of CHT. The CHT Marks are proprietary to CHT and nothing in this Agreement constitutes the grant of a general license for their use. Other than as expressly set forth herein, Ehave does not acquire any right, title or interest in or to any CHT Marks or the goodwill associated therewith. CHT reserves any and all rights in and to the CHT Marks not expressly granted herein. 4. CHT DEVELOPMENTS (a) Development From time to time, CHT may request Ehave to develop functionality that is separate from, but interfaces with the Ehave Companion Solution (the CHT Developments). Any such development effort shall be subject to a separate services agreement between the Parties which will set out the respective obligations of the Parties regarding the development and deployment of any CHT Developments, including without limitation assignment or transfer of any rights that Ehave may have in such CHT Developments. (b) APIs If CHT desires a third party to develop any CHT Developments, Ehave shall provide to CHT the specifications of the application program interfaces to permit CHT or such other third party to develop the CHT Developments so that it may inter-operate with the Ehave Companion Solution. (c) License If CHT requires Ehave to host the CHT Developments, then CHT hereby grants to Ehave a royalty-free, non-exclusive, non-transferable, limited right and licence during the Term hereof to use the CHT Developments solely for the purpose of enabling its operation for CHT and its End Users' purposes. 5. GENERAL PERFORMANCE OBLIGATIONS (a) Marketing CHT shall, in good faith and at its own expense: (i) market, advertise, promote and re-license the use of the Ehave Companion Solution to End Users located in the Territory consistent with good business practice, provided that CHT shall have full discretion as to where in the Territory it chooses to do so at any time and from time to time;

9.

Source: EHAVE, INC., 20-F, 5/15/2019





(ii) develop and execute a marketing plan sufficient to fulfil its obligations under this Agreement; (iii) have sufficient knowledge of the industry and solutions competitive with the Ehave Companion Solution (including specifications, features and benefits) so as to be able to explain in detail to the End Users: A. the material differences between the Ehave Companion Solution and competing solutions; and B. information on standard protocols and features of the Ehave Companion Solution; (iv) market, advertise, promote and provide the Ehave Companion Solution and conduct business in a manner that at all times reflects favourably on the Ehave Companion Solution and, subject to Section 3(f), the good name, goodwill and reputation of Ehave; and (v) maintain books, records and accounts of all transactions and activities covered by this Agreement and permit reasonable examination thereof by Ehave and its representatives in accordance with this Agreement. (b) Provision to End Users CHT shall require each End User to enter into and execute a subscription agreement in a form and substance satisfactory to Ehave and CHT, acting reasonably, and which contains provisions similar to Ehave's collaboration agreement for the use of the Ehave solution (the Subscription Agreement). Ehave shall be a third party beneficiary hereunder, but shall not have any obligations to the End User thereunder. (c) End User Data Pursuant to the Subscription Agreement, CHT shall obtain from each End User the right to and hereby grants, effective upon the execution and delivery of such End User's Subscription Agreement, to Ehave: (i) a royalty-free, non-exclusive, non-transferable, limited right and licence during the term of such Subscription Agreement to use, copy, store and display the End User Data solely for the purpose of enabling Ehave to operate the Ehave Companion Solution for such End User and as may be necessary for the purpose of enabling Ehave to provide support services in accordance with this Agreement; and (ii) a royalty-free, non-exclusive, limited, perpetual right and license to use, copy, store and display End User Data on an aggregated and anonymous basis and so as not to permit the identification of any End User or individual for the sole purpose of improving or developing enhancements to the Ehave Companion Solution , provided that Ehave shall not have any right to use, commercialize or exploit such End User Data in any other manner or for any other purpose. Except for the limited license expressly provided in Section 5(c), nothing contained in this Agreement shall be construed as granting to Ehave or any third party any right, title, or interest in or to any End User Data. Without limiting the foregoing, Ehave agrees that it shall not (i) modify, alter or commercially exploit any End User Data; or (ii) distribute or sell, rent, lease, license or otherwise make any End User Data available to any third party (other than the particular End User to whom the End User Data pertains and its Authorized Users).

10.

Source: EHAVE, INC., 20-F, 5/15/2019





(d) Authority to Perform Under this Agreement Each Party shall, at its own expense, obtain and maintain required certifications, credentials, licences and permits necessary to conduct business in accordance with this Agreement. CHT shall obtain all necessary licenses, permits, certifications and credentials to conduct its business. (e) End User Support On and after the launch of the Ehave Companion Solution, CHT shall, at its own expense, ensure that an adequate number of trained, capable and qualified technical personnel with sufficient knowledge of the Ehave Companion Solution are available to provide first line support to assist End Users. If CHT's support personnel are unable to resolve any trouble tickets from an End User, CHT may escalate the trouble ticket to Ehave in accordance with the support procedures set out in Schedule 3. On and after the launch of the Ehave Companion Solution, Ehave shall ensure that an adequate number of trained, capable and qualified technical personnel with sufficient knowledge of the Ehave Companion Solution are available to provide support in accordance with the support procedures set out in Schedule 3. (f) Government Approval If, at any time during the Term, any notification, registration or approval is required to give legal effect in any applicable jurisdiction to this Agreement or the transactions contemplated under this Agreement, CHT shall: (i) immediately take whatever steps may be necessary to properly notify, register or obtain approval; (ii) be responsible for any charges incurred in connection with notifying, registering or obtaining this approval; and (iii) keep Ehave currently informed of its efforts regarding this Section 5(f). Ehave is not obligated to provide access to the Ehave Companion Solution in a particular jurisdiction under this Agreement until CHT has provided Ehave with satisfactory evidence that: (i) this approval, notification or registration is not required or that (ii) it has been obtained. At CHT's cost and expense, Ehave shall provide reasonable assistance and cooperation to CHT as CHT may reasonably request in its efforts to obtain or provide any such approval, notification or registration, provided that, CHT shall at all times retain full discretion as to where in the Territory it chooses to market, promote, advertise and/or sublicense the Ehave Companion Solution. (g) Prohibited Acts Notwithstanding anything to the contrary in this Agreement, neither CHT nor CHT personnel shall: (i) make any representations, conditions, warranties, guarantees, indemnities, similar claims or other commitments: A. actually, apparently or ostensibly on behalf of Ehave, or B. to any End User regarding the Ehave Companion Solution, which representations, conditions, warranties, guarantees, indemnities, similar claims or other commitments are additional to or inconsistent with any then-existing representations, conditions, warranties, guarantees, indemnities, similar claims or other commitments in this Agreement or any written or electronic documentation provided by Ehave to CHT; or

11.

Source: EHAVE, INC., 20-F, 5/15/2019





(ii) engage in any unfair, competitive, misleading or deceptive practices respecting Ehave, Ehave's Trade-marks or the Ehave Companion Solution, including any product disparagement or bait-and-switch practices. 6. EHAVE COMPANION SOLUTION (a) Provision and Access to Ehave Companion Solution Once deployed, Ehave shall operate, support and maintain the Ehave Companion Solution in accordance with the terms of this Agreement, including the Support Procedures set out in Schedule 3, the Service Level Commitments set out in Schedule 4 and the Security Requirements set out in Schedule 5. Access to the Ehave Companion Solution may be through a secure connection with the public Internet. CHT acknowledges and agrees that Ehave is not responsible or liable for any communication over the public Internet. (b) Security Requirements Ehave shall implement and maintain those safeguards and controls set out in Schedule 5 to deter and for the detection, prevention and correction of any unauthorized intrusion, access or use of the Ehave Companion Solution, as well as to protect against any loss, theft or unauthorized access, use, disclosure, copying, or modification of End User Data. CHT acknowledges and agrees, and shall obtain such acknowledgement and agreement from its End Users, that notwithstanding the Security Requirements, such methods and procedures may not prevent unauthorized electronic intruders to access the Ehave Companion Solution through the Internet or through other form of electronic communication. If such unauthorized electronic intruders are able to bypass Ehave's security protocols, firewall and safeguards, such unauthorized electronic intruder may change, delete or otherwise corrupt the contents and data contained in the Ehave Server, including any End User Data. Except for the maintenance of appropriate firewall and safeguards in compliance with the Security Requirements, which are designed to frustrate access from unauthorized electronic intruders, Ehave shall not be liable to CHT or to any of its End users, and hereby disclaims responsibility, with respect to any action, destructive or otherwise, by any unauthorized electronic intruder. (c) Maintenance From time to time, it will be necessary for Ehave to perform maintenance on the Ehave Companion Solution. Such maintenance includes routine maintenance to ensure the continued provision of the Ehave Companion Solution or upgrading, updating or enhancing the Ehave Companion Solution. Ehave shall use its commercially reasonable efforts to perform such maintenance at such times within the designated maintenance windows set forth in Schedule 3 to minimize the impact of any downtime of the Ehave Platform to CHT and its End Users. To the extent Ehave is able, Ehave shall notify CHT at least 48 hours in advance of any scheduled maintenance by sending an email to the designated CHT Service Manager of the scheduled maintenance time and the anticipated duration of such maintenance. (d) Changes to Service Ehave may, at any time, with or without written notice (except in cases where such change may affect the manner in which the Services are delivered, in which case, Ehave shall use reasonable efforts to provide advance written notice, but in any event as soon as reasonably possible thereafter) to CHT (i) make changes to the Ehave Companion Solution that are necessary to comply with applicable safety, security or other statutory requirements or orders from applicable Governmental Authorities; (ii) supplement or make changes to its user documentation and to its rules of operations, access procedures, security and privacy procedures and policies, provided such changes do not materially adversely affect CHT or its End Users; and (iii) change the components, type and location of the Ehave Platform, provided that such changes do not adversely affect the performance, features, functionality or security of the Ehave Companion Solution.

12.

Source: EHAVE, INC., 20-F, 5/15/2019





(e) Authentication IDs CHT shall, and shall require its End Users to, control and maintain the security of all Authentication IDs. As between CHT and Ehave, CHT shall be solely responsible for all instructions, commitments and other actions or communications taken under any of CHT's Authentication IDs. CHT shall promptly report to Ehave any errors or irregularities in the Ehave Companion Solution or the Ehave Platform or any unauthorized use of any part thereof that come to CHT's attention and inform Ehave immediately if CHT becomes aware that any Authentication ID becomes known to any third person who is not authorized to possess such password. (f) End User Data CHT acknowledges and agrees that Ehave: (i) will not be responsible for the accuracy, completeness or adequacy of any End User Data or the results generated from any End User Data uploaded to and processed by the Ehave Companion Solution in accordance with the Specifications; (ii) has no control over any End User Data or the results therefrom; (iii) does not purport to monitor End User Data; and (iv) shall not be responsible to back up or maintain any back up of the End User Data or portion thereof. (g) Viruses If Ehave, in its absolute discretion, forms the view that any End User Data or any other information or files uploaded by CHT or any of its End User and their Authorized Users contains or includes a Virus or is reasonably considered Objectionable Content, Ehave may remove such End User Data, information or file from the Ehave Companion Solution and take such other action as Ehave deems necessary to protect the integrity and operation of the Ehave Companion Solution. Any reasonable costs associated with such removal may be charged by Ehave to CHT. Ehave shall notify CHT of its actions under this Section 6(g) as soon as reasonably possible. 7. ROYALTIES AND PAYMENT (a) Royalties The Royalties and payment terms are as set out in Schedule 6. The Royalties do not include applicable taxes. CHT agrees to pay the Royalties and applicable taxes in accordance with the payment terms as set out in Schedule 6. (b) Taxes: CHT shall pay any and all applicable taxes, however designated or incurred, which are payable by it pursuant to Applicable Law as a result of or otherwise in connection with the transactions contemplated in this Agreement including, without limitation, federal, provincial and local, excise, sales, use, goods and services, harmonized, value added and any similar taxes, except for any taxes based on Ehave's net income. (c) Interest on Late Payments: Where CHT fails to pay any amount in accordance with the payment terms set out in Schedule 6, Ehave shall have the right, in addition to any other rights or remedies available to it, to charge, and CHT shall pay, interest on such overdue amounts at the rate of 1% per month calculated daily, compounded monthly (12.68% per annum) both before and after any court judgement in respect of the same from the date such payment was due.

13.

Source: EHAVE, INC., 20-F, 5/15/2019





8. AUDIT RIGHTS (a) Ehave Right to Audit CHT will provide Ehave and its representatives, auditors and inspectors (Auditors) upon ten (10) Business Days prior written notice with reasonable access, during business hours, to all facilities, systems and assets used by CHT, to CHT personnel and subcontractors and to all relevant CHT books and records, in each case, to the extent relevant to this Agreement, in order to conduct appropriate audits, examinations and inspections (Audits) to: (i) verify compliance with the requirements set out in this Agreement; and (ii) verify the Royalty calculations. (b) Principles Regarding Audits CHT shall provide to Ehave and its Auditors any assistance they may reasonably require to conduct such Audits. Audits may be conducted once a calendar year, provided that the foregoing limit shall not apply where an audit discovered an overcharge of 5% or more, in which case, Ehave may conduct another audit sooner. No period shall be audited more than once. Costs incurred by Ehave in connection with any audit or inspection conducted shall be borne by Ehave. Notwithstanding the foregoing, if an Audit reveals that CHT underpaid Ehave for any Royalties hereunder, by more than five percent (5%) of the total Royalties paid during the period being audited, CHT shall promptly reimburse Ehave for all reasonable third party expenses incurred by Ehave in connection with such Audit. In all cases CHT shall promptly pay Ehave in full for any underpayments revealed by an Audit. All information obtained by Ehave and its Auditors during any such Audit shall be kept confidential and shall be considered CHT's Confidential Information. Ehave shall impose confidentiality obligations on its Auditors that are substantially similar to those under Section 13 and shall be responsible for any breach of confidentiality by its Auditors. (c) Records CHT shall keep detailed records and books of account with supporting vouchers, invoices and other documentation showing all expenditures, charges and related calculations of whatsoever nature made by it in the performance of its obligations under this Agreement. CHT shall retain such records for the greater of: (i) three (3) years; or (ii) the period required by Applicable Laws. (d) Security Audit On an annual basis, Ehave shall conduct and provide CHT the results of an audit conducted in accordance with the Statement on Standards for Attestation Engagements (SSAE) No. 18, Service Organization Control (SOC) 2 Report type audit or similar audits in respect of its operations. Ehave shall also provide CHT written notice and detail of any deficiencies that Ehave's auditors (whether internal or external) found through the conduct of such audits and the remediation efforts that Ehave shall undergo to rectify such deficiencies. Ehave shall promptly rectify any deficiencies identified that may materially and adversely impact the Ehave Companion Solution or End User Data, and shall provide CHT with such information as CHT may reasonably request from time to time with respect to its security controls including any remediation efforts undertaken to rectify any deficiencies. 9. TERM This term of this Agreement and the rights and obligations of the Parties hereto shall commence as of the Effective Date and shall continue in perpetuity (the Term), unless terminated earlier in accordance with the provisions contained herein.

14.

Source: EHAVE, INC., 20-F, 5/15/2019





10. SUSPENSION AND TERMINATION (a) Suspension of Services: Subject to the provisions of this Section, in the event that CHT does not pay the Royalties or any portion thereof, when due, Ehave may immediately suspend CHT's and each of its End Users' right to access and use the Ehave Companion Solution. However, Ehave shall not suspend CHT's or its End Users' right to access and use the Ehave Companion Solution or any End User Data by reason of CHT's good faith withholding of any payment or amount, or in the event of any payment dispute between the parties arising under or concerning this Agreement, in each case, unless and until such dispute is resolved pursuant to Section 19, provided that CHT shall have a period of five (5) Business Days to pay any amount agreed to in settlement or determined by arbitration pursuant to Section 19 to be payable by it. (b) CHT's Right to Terminate: Subject to Sections 10(e) and 10(g), CHT may terminate this Agreement and the rights granted hereunder, in whole or in part, without prejudice to enforcement of any other legal right or remedy (including any express termination right set forth elsewhere in this Agreement), immediately upon giving written notice of such termination if Ehave: (i) breaches any material provision of this Agreement and such breach continues for a period of twenty (20) Business Days after delivery of a written notice by CHT requiring Ehave to correct such failure; or (ii) becomes or is adjudicated insolvent or bankrupt, admits in writing its inability to pay its debts as they mature, or makes an assignment for the benefit of creditors; or Ehave applies for or consents to the appointment of any receiver, trustee or similar officer for it or for all or any substantial part of its property; or such receiver, trustee or similar officer is appointed without the consent of Ehave; or Ehave institutes any bankruptcy, insolvency, reorganization, moratorium, arrangement, readjustment or debt, dissolution, liquidation or similar proceeding relating to it under the laws of any jurisdiction, or any such proceeding is instituted against Ehave and is not dismissed within sixty (60) Business Days; or any judgment, writ, warrant or attachment or execution of similar process is issued or levied against a substantial part of Ehave's property and remains unsatisfied for sixty (60) Business Days. In addition, CHT may terminate this Agreement and the rights granted hereunder, in whole or in part, and without prejudice to enforcement of any other legal right or remedy (including any express termination right set forth elsewhere in this Agreement), at any time without cause, by providing at least thirty (30) Business Days prior written notice to Ehave, but subject to payment of a termination fee equal to an amount set out in Schedule 6. (c) Ehave's Right to Terminate: Subject to Sections 10(e) and 10(g), Ehave may terminate this Agreement and the rights granted hereunder without prejudice to enforcement of any other legal right or remedy, immediately upon giving written notice of such termination if CHT: (i) fails to pay in full any sum owing by it under this Agreement by the due date thereof (other than any sum the payment of which is disputed by CHT in good faith and withheld pending resolution of such dispute in accordance with Section 19) and such failure continues for a period of ten (10) Business Days after delivery of a written notice by Ehave requiring CHT to correct such failure;

15.

Source: EHAVE, INC., 20-F, 5/15/2019





(ii) breaches any other material provision of this Agreement and such breach continues for a period of twenty (20) Business Days after delivery of a written notice by Ehave requiring CHT to correct such failure; or (iii) becomes or is adjudicated insolvent or bankrupt, admits in writing its inability to pay its debts as they mature, or makes an assignment for the benefit of creditors; or CHT applies for or consents to the appointment of any receiver, trustee or similar officer for it or for all or any substantial part of its property; or such receiver, trustee or similar officer is appointed without the consent of CHT; or CHT institutes any bankruptcy, insolvency, reorganization, moratorium, arrangement, readjustment or debt, dissolution, liquidation or similar proceeding relating to it under the laws of any jurisdiction, or any such proceeding is instituted against CHT and is not dismissed within sixty (60) Business Days; or any judgment, writ, warrant or attachment or execution of similar process is issued or levied against a substantial part of CHT's property and remains unsatisfied for sixty (60) Business Days. (d) Waiver: The waiver by either Party of a breach or default of any provision of this Agreement by the other Party shall not be effective unless in writing and shall not be construed as a waiver of any succeeding breach of the same or of any other provision. Nor shall any delay or omission on the part of either Party to exercise or avail itself of any right, power or privilege by such Party shall constitute a waiver. (e) Effect of Termination: Upon the termination of this Agreement for any reason, subject to and without limiting the provisions of Section 12: (i) the Parties shall implement the Transition-Out Services pursuant to Section 10(f); (ii) at the end of the Transition-out Period (or earlier upon CHT's request) Ehave shall terminate and invalidate any Authentication IDs associated with CHT and any of its End Users; (iii) Ehave shall, but not earlier than twenty (20) Business Days after the later of termination or expiration of this Agreement or the Transition-out Period, destroy any copies of the End User Data contained in the Ehave Companion Solution and certify in writing to CHT that it has done so; (iv) CHT shall pay to Ehave the full amount of all Royalties payable hereunder as of the date of termination, if any, whether already invoiced or not (including any amounts due as late payment charges), and any other monies owing to Ehave hereunder; and (v) each Party will return to the other Party, or at the other Party's written request, destroy, in a secure manner all Confidential Information of the other Party which is then in its possession or control and certify in writing that it has done so. CHT acknowledges and agrees if any End User fails to download its End User Data from the Ehave Companion Solution in a timely manner (i.e. on or before the later of termination or expiry of this Agreement and the Transition-out Period), it may not have access to such information or such information may be destroyed by Ehave in accordance with the terms of this Section 10(e). Subject to Section 10(f), it is CHT's and each End User's responsibility to download and obtain all the End User Data on or prior to the termination of this Agreement or expiry of the Transition-out Period (whichever is later). Ehave shall have no responsibility for maintaining or providing to CHT or to any of its End Users the End User Data or any portion thereof, or any liability to CHT or any End User for destroying End User Data, in either case, from and after the twentieth (20th) Business Day after the termination or expiration of this Agreement or the Transition-out Period, whichever later.

16.

Source: EHAVE, INC., 20-F, 5/15/2019





(f) Transition Assistance: Without limiting the provisions of Section 11, commencing on the delivery of any notice of termination of this Agreement, and continuing through the effective date of termination and for a period of sixty (60) Business Days thereafter (the Transition-out Period), Ehave will, to the extent requested by CHT, provide to CHT (or at CHT's request to CHT's End User) such reasonable cooperation, assistance and services to facilitate the orderly wind down, transition and migration and transfer of the End User Data from Ehave to CHT (the Transition-out Services). (g) Survival of Covenants: Notwithstanding the termination or expiration of this Agreement for any reason, the covenants set out in this Section 10(g) and in Sections 7(c), 10(e), 10(f), 11, 12, 13, 14(c), 15, 16, 17, 19, 20(a) and those provisions set out in Section 1 as necessary to interpret the foregoing provisions, of this Agreement shall survive any such termination or expiration. 11. OWNERSHIP (a) Ehave's Ownership CHT acknowledges and agrees that, as between CHT and Ehave, Ehave owns all worldwide right, title and interest, including all Intellectual Property Rights, in and to the Ehave Companion Solution, including any developments, enhancements or customizations made as a result of Section 3 and any modifications, enhancements, upgrades, updates or Customization subsequent to the development and implementation in accordance with Section 3, excluding, however, any CHT Developments. CHT does not acquire any rights, title or ownership interests of any kind whatsoever, express or implied, in any of the foregoing other than the licenses granted herein. (b) CHT's Ownership Ehave acknowledges and agrees that, as between Ehave and CHT, CHT owns all worldwide right, title and interest, including all Intellectual Property Rights, in and to the CHT Developments. Ehave does not acquire any rights, title or ownership interests of any kind whatsoever, express or implied, in any of the foregoing other than the licenses granted herein. Further, as between CHT and Ehave, (i) CHT (or its End User) is and will remain the sole and exclusive owner of all right, title, and interest in and to End User Data, including all Intellectual Property Rights therein and/or relating thereto, subject only to the limited license granted in Section 5(c), and (ii) End User Data and CHT Developments are and will be the Confidential Information of CHT. CHT and End Users shall at all times, including in the event of termination of this Agreement and for a period thereafter as set out in Section 10(e), have access to their respective End User Data and the ability to download and/or export their End User Data out of the Ehave Companion Solution.

17.

Source: EHAVE, INC., 20-F, 5/15/2019





12. ESCROW (a) Escrow Agreement (i) Concurrently with execution of this Agreement or, at CHT's option, as soon as practicable after the Effective Date but in no event later than CHT's acceptance of and the launch of the Ehave Companion Solution, CHT and Ehave shall enter into a Source Code Escrow Agreement with a reputable software escrow agent mutually acceptable to the Parties (Escrow Agent), in or substantially in the form attached hereto as Schedule 7, or otherwise in a form acceptable to the Parties, acting reasonably, and to the Escrow Agent (the Escrow Agreement), providing for the release of the Source Code for the Software, as modified pursuant to Section 3 and all necessary programming documentation, utilities and tools used by Ehave to maintain the Software and to compile the source code into object code (excluding third party utilities and tools licensed by Ehave for which Ehave has not been granted the right to sublicense or otherwise make available such utilities and tools to third parties without additional charge, but including such information as necessary for CHT to obtain licenses to and obtain such third party utilities and tools), all in its then-existing form, to CHT, in the certain circumstances expressly stated in Section 12(b). The Escrow Agreement shall provide that the Software, including the Source Code and object code, Specifications and related documentation are and shall be deemed to be intellectual property and the rights under the Escrow Agreement and the license granted under Section 12(a)(iii) are deemed to be rights to use intellectual property for purposes of section 65.11(7) of the BIA and section 32(6) of the CCAA. (ii) Upon release of the Source Code by the Escrow Agent to CHT pursuant to the terms and conditions of the Escrow Agreement, Ehave hereby warrants that such Source Code and other materials are and will be the then current version of the Software as used by CHT in its provision to End Users of the eEhave Companion Solution under the Subscription Agreements and that Ehave shall throughout the Term keep the Source Code so deposited with the Escrow Agent current by periodically submitting material updates to the Escrow Agent from time to time, as necessary. Save and except for express warranties specified in this Agreement and the Escrow Agreement, Ehave specifically disclaims all other warranties, express or implied, including, without limitation, any warranty of merchantability and fitness for a particular purpose. (iii) In connection with the exercise of CHT's rights under the Escrow Agreement, Ehave hereby grants to CHT a non- exclusive, non-transferable (except as set forth in Section 20(f)), right and license to use and copy the materials deposited with the Escrow Agent, including the Source Code, its Specifications and documentation, and any resulting corrections, repairs, translations, enhancements, and other derivative works and improvements made by CHT, for the sole purposes of providing to CHT the ability to operate, support and maintain, the Ehave Companion Solution for its End Users from time to time, until such time that CHT is able to migrate off the Ehave Companion Solution, but in any event not exceeding twelve months from the date of release of the materials from escrow. CHT may use third parties to perform its foregoing rights, provided that any such third parties are not competitors of Ehave and shall be subject to confidentiality obligations. CHT expressly agrees, however, that CHT shall not exercise any of the foregoing right and license unless and until CHT obtains such Source Code from the Escrow Agent. CHT's obligations with respect to confidentiality and use of the Source Code shall be equivalent to CHT's obligations set forth in Section 13 of this Agreement. Notwithstanding any release of the Source Code pursuant to the provisions hereof, Ehave shall retain sole ownership of and other proprietary rights with respect to the Source Code (including any Source Code relating to any modifications made by CHT to the Source Code, all of which shall be owned by Ehave). CHT shall be responsible for all of the Escrow Agent's fees and charges under the Escrow Agreement.

18.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Release Conditions The parties acknowledge and agree that a Release Condition for purposes of the Escrow Agreement shall be deemed to mean any one or more of the following listed events (in addition to any other event specified as a release condition under the Escrow Agreement): (i) Ehave makes a general assignment for the benefit of creditors; (ii) Ehave voluntarily institutes any bankruptcy, insolvency, reorganization, moratorium, arrangement, readjustment or debt, dissolution, liquidation or similar proceeding relating to it under the laws of any jurisdiction, or any such proceeding is instituted against Ehave and is not dismissed within sixty (60) Business Days; or any judgment, writ, warrant or attachment or execution of similar process is issued or levied against a substantial part of Ehave's property and remains unsatisfied for sixty (60) Business Days; or Ehave applies for or consents to the appointment of any receiver, trustee or similar officer for it or for all or any substantial part of its property; or such receiver, trustee or similar officer is appointed without the consent of Ehave; (iii) Ehave consents to the filing of a petition of bankruptcy against it; (iv) a petition of bankruptcy is filed against Ehave which is not discharged within sixty (60) days; (v) Ehave becomes or is adjudicated by a court of competent jurisdiction as being bankrupt or insolvent or admits in writing its inability to pay its debts as they mature; Ehave ceases doing business as a going concern; (vi) Ehave undergoes a change of control or is a party to a merger or amalgamation; (vii) Ehave takes steps to dissolve, liquidate, wind up or otherwise terminate its existence; (viii) Ehave has terminated its provision of or ceased to provide the Ehave Companion Solution or support services for a continuing period of fifteen (15) Business Days or more, except pursuant to the termination of this Agreement by Ehave in accordance with its rights contained hrein. (c) Effect of Bankruptcy All of the Software, including the Source Code and object code, the Specifications and related documentation, and all other escrow deposit materials constitute intellectual property and all rights and licenses granted by Ehave to CHT under this Agreement or the Escrow Agreement (which is supplementary to this Agreement) are and shall be deemed to be licenses and rights to use intellectual property by CHT for the purposes of and as such terms are used and interpreted under section 65.11(7) of the BIA and section 32(6) of the CCAA. CHT shall have the right to exercise all rights and elections under the BIA and CCAA and all other applicable bankruptcy, insolvency and similar laws with respect to this Agreement, the Escrow Agreement and the subject matter hereof and thereof. Without limiting the generality of the foregoing, if Ehave or its estate becomes subject to any bankruptcy or similar proceeding subject to CHT's rights of election, all rights and licenses granted to CHT under this Agreement and the Escrow Agreement will continue subject to the respective terms and conditions hereof and thereof, and will not be affected, even by Ehave's rejection of this Agreement or the Escrow Agreement.

19.

Source: EHAVE, INC., 20-F, 5/15/2019





13. CONFIDENTIALITY (a) Obligation: Each Party acknowledges that all Confidential Information consists of confidential and proprietary information of the disclosing Party. Each Party shall, and shall cause its employees, agents and contractors to hold Confidential Information of the other Party in confidence, and shall use the same degree of care by instruction, agreement or otherwise, to maintain the confidentiality of the other Party's Confidential Information that it uses to maintain the confidentiality of its own Confidential Information, but with at least a reasonable degree of care commensurate with the nature and importance of such Confidential Information. Each Party agrees not to make use of Confidential Information other than for the exercise of rights or the performance of obligations under this Agreement (and the Source Code Escrow Agreement), and not to release, disclose, communicate it or make it available to any third person other than employees, agents and contractors of the Party who reasonably need to know it in connection with the exercise of rights or the performance of obligations by such Party under this Agreement (and the Source Code Escrow Agreement) and who are bound by confidentiality and restricted use obligations at least as protective of the Confidential Information as those set forth herein. Each Party agrees to notify the other Party in writing promptly of any loss or unauthorized disclosure or use of such other Party's Confidential Information and cooperate with such other Party to protect the confidentiality and ownership of all Intellectual Property Rights and other rights therein. (b) Subpoena: In the event that any Party receives a request to disclose all or any part of the Confidential Information of the other Party under the terms of a valid and effective subpoena or order issued by a court of competent jurisdiction or by a Governmental Authority, such Party agrees to (i) immediately notify the other Party of the existence, terms and circumstances surrounding such a request; (ii) consult with the other Party on the advisability of taking legally available steps to resist or narrow such request; and (iii) if disclosure of such Confidential Information is required, exercise its commercially reasonable efforts to obtain, and/or assist the other Party to obtain, at the other Party's expense, an order or other reliable assurance that confidential treatment will be accorded to such portion of the disclosed Confidential Information which the other Party so designates. (c) Injunctive Relief: Each Party acknowledges and agrees that any unauthorized use or disclosure by it of any of the other Party's Confidential Information, in whole or part, will cause irreparable damage to the disclosing Party, that monetary damages would be an inadequate remedy and that the amount of such damages would be extremely difficult to measure. The receiving Party agrees that the disclosing Party shall be entitled to seek temporary and permanent injunctive relief to restrain the receiving Party from any unauthorized disclosure or use. Nothing in this Agreement shall be construed as preventing the disclosing Party from pursuing any and all remedies available to it for a breach or threatened breach of a covenant made in this Section 13, including the recovery of monetary damages from the receiving Party.

20.

Source: EHAVE, INC., 20-F, 5/15/2019





14. REPRESENTATIONS, WARRANTIES AND DISCLAIMERS (a) Mutual Representations of the Parties: Each Party represents to the other that: (i) it is a company duly organized, validly existing and in good standing under the laws of its incorporation and it has full power and authority to enter into this Agreement and to perform each and every covenant and agreement herein contained; (ii) this Agreement has been duly authorized, executed and delivered by it and constitutes a valid, binding and legally enforceable agreement of it; (iii) the execution and delivery of this Agreement, and the performance of the covenants and agreements herein contained, are not, in any manner or to any extent, limited or restricted by, and are not in conflict with, any commercial arrangements, obligations, contract, agreement or instrument to which it is either bound or subject; and (iv) the execution and delivery of this Agreement and the performance of its covenants and agreements herein contained shall comply in all respects with all laws and regulations to which it or its business is subject. (b) Additional representations of Ehave: Ehave represents to CHT that Ehave possesses the knowledge, skill and experience necessary for the provision and completion of the Ehave Companion Solution in accordance with the terms of this Agreement. (c) Warranties Ehave warrants that for the duration of the Term, (i) the Ehave Companion Solution will substantially conform to and operate in accordance with, and have the functions and features set out in, the Specifications, and any related documentation provided by Ehave, and any such documentation shall be complete and accurate in all material respects; and the Ehave Companion Solution will not contain any material undocumented feature; (ii) Ehave has implemented and will maintain industry standard protection for the detection, protection and removal of Viruses; (iii) Ehave will perform all services under this Agreement in a timely, professional and workmanlike manner using personnel of required skill, experience and qualifications, and will devote adequate resources to meet its obligations (including the Service Level Commitments and its support obligations) hereunder; (iv) it has or will have all necessary right, power and authority, including all licenses and Intellectual Property Rights required, to provide and operate the Ehave Companion Solution and to grant all rights and licenses granted or required to be granted by it under this Agreement; and (v) Ehave is not aware of any infringement or misappropriation claims by any third party in relation to the Ehave Companion Solution.

21.

Source: EHAVE, INC., 20-F, 5/15/2019





(d) Exclusion of Other Warranties: Except as otherwise expressly stated in this Agreement, there are no express or implied warranties or conditions in relation to the Ehave Companion Solution that are the subject matter of this Agreement, including implied warranties or conditions of merchantable quality, fitness for a particular purpose, or non-infringement, or that the Ehave Companion Solution will meet CHT's or any End Users' needs or will be available for use at any particular time or will be error free. Under no circumstances will Ehave be liable for the results of CHT or any of its End Users' misuse of the Ehave Companion Solution, including any use contrary to Applicable Law. 15. INSURANCE (a) Required Insurance: Both Parties shall, at all times during the currency of this Agreement and for a period of one (1) year after the termination or expiration of this Agreement, maintain the following policies of insurance in effect: (i) a comprehensive general liability insurance policy, with minimum coverage of $1,000,000 per occurrence and in the annual aggregate for product liability and completed operations, covering bodily and personal injury, including death, and property damage, including loss of use; and (ii) an information and network technology blended liability insurance policy with an insured limit of at least $1,000,000 in the aggregate. (b) Evidence of Insurance: Upon the execution of this Agreement or at any time at a Party's request during the term of this Agreement, the other Party shall provide the requesting Party with evidence of the aforementioned insurance coverage in the form of a certificate of insurance acceptable to the requesting Party. In the event of any material change or cancellation of the required insurance policies, the applicable Party will provide the other Party with thirty (30) calendar days' prior written notice and will promptly replace such insurance policy in accordance with this Section 15, without lapse in coverage. 16. INDEMNITIES (a) Intellectual Property Indemnity Ehave shall defend at its own expense any claim, proceeding or suit (a Claim) brought against CHT and/or any of its directors, officers, employees, agents, subcontractors, affiliates and/or End Users (collectively, the CHT Indemnified Parties) to the extent such Claim alleges that the Ehave Companion Solution furnished hereunder or the use thereof by CHT or its End Users as authorized hereunder or in any Subscription Agreement infringes any copyright, Canadian patent, or registered trademark of a third person, and will indemnify and hold harmless the CHT Indemnified Parties from and against any and all related liabilities, costs, losses, damages and expenses (including reasonable legal fees) arising out of or in connection with or relating to any such Claim, provided that: (i) Ehave is given prompt written notice of the Claim or of any allegations or circumstances known to CHT which could reasonably result in a Claim; (ii) Ehave is given all reasonable information and assistance from CHT, at Ehave's expense, which Ehave may require to defend the Claim;

22.

Source: EHAVE, INC., 20-F, 5/15/2019





(iii) Ehave is given sole control of the defence of the Claim, and all negotiations for the settlement or compromise thereof, provided that Ehave shall promptly engage competent counsel and initiate defence in a professional manner and CHT may observe or participate in such proceedings with its own counsel at its own expense; and (iv) the alleged infringement does not result from any non-permitted uses, alterations, modifications or enhancements carried out by CHT, any End User or on its or their behalf by a third person (other than any Ehave personnel or contractors). If such Claim has occurred, or in Ehave's opinion is likely to occur, without limiting Ehave's obligation to defend and indemnify the CHT Indemnified Parties as aforesaid, Ehave may, at its option and expense, either procure for CHT the right to continue using the Ehave Companion Solution in accordance with this Agreement or modify or replace the same so that it becomes non-infringing without loss of functionality, or if none of the foregoing alternatives is reasonably available and at Ehave's discretion, discontinue the use of the Ehave Companion Solution on not less than sixty (60) Business Days' prior written notice to CHT and its End Users. The foregoing states the entire obligations of Ehave with respect to any infringement of Intellectual Property Rights of any third Person. (b) CHT' Indemnity CHT shall defend at its own expense any Claim brought against Ehave, its affiliates, directors, officers, employees and agents, to the extent such Claim: (i) alleges, directly or indirectly, that any End User Data infringes any Canadian copyright, patent or registered trademark of a third person; alleges, directly or indirectly, that the End User Data contains any Objectionable Content; (ii) arises through a breach by CHT of its obligations set out in Section 5(g); or (iii) is in relation to any of its End Users' use of the Ehave Companion Solution, including contrary to Applicable Law, except however to the extent as Ehave has indemnified CHT pursuant to Section 16(a); provided that CHT is given: (i) prompt written notice of the Claim or of any allegations or circumstances known to Ehave which could result in a Claim; (ii) all reasonable information and assistance from Ehave, at CHT's expense, which CHT may require to defend the Claim; and (iii) sole control of the defence of the Claim, and all negotiations for its settlement or compromise thereof. 17. LIMITATION OF LIABILITY (a) Consequential Damages Subject to Section 17(c), in no event shall either Party be liable to the other for any consequential, incidental, exemplary or punitive damages even if advised in advance of the possibility of such damages. Further, subject to Section 17(c), neither Party shall not be liable to the other Party for any lost revenue, lost profit or lost savings. (b) Limitation of Direct Damages Subject to Section 17(c), in no event shall either Party's liability under this Agreement exceed the aggregate of all amounts paid under this Agreement and amounts that have accrued but not yet been paid in the twelve (12) months preceding the event giving rise to the claim.

23.

Source: EHAVE, INC., 20-F, 5/15/2019





(c) Exceptions to Limitations Notwithstanding Sections 17(a) and 17(b), neither Party excludes or limits any liability for: (i) personal injury or death to the extent that such injury or death results from the negligence or wilful misconduct of a Party or its employees or subcontractors; (ii) fraud, fraudulent misrepresentation or fraudulent concealment; (iii) the Party's obligations set out in Sections 2(c), 5(b), 5(c), 6(b), 11, 13 or 16; (iv) CHT's payment obligations under Section 7; or (v) willful misconduct or gross negligence. (d) Application of Limitations and Exclusions The limitations and exclusions set out in this Section shall apply whether a claim, demand or action is based in contract, tort (including negligence), or otherwise. 18. FORCE MAJEURE Except for any obligation to make payments, any delay or failure of either Party to perform its obligations under this Agreement or under any Schedule attached hereto shall be excused if, and to the extent, that the delay or failure is caused by an event or occurrence beyond the reasonable control of the Party and without its fault or negligence and that could not have been prevented or avoided by the exercise of reasonable due diligence, such as, by way of example and not by way of limitation, acts of God, action by any Governmental Authority (whether valid or invalid), fires, flood, wind storms, explosions, riots, natural disasters, wars, terrorist acts, sabotage, labour problems (including lock-outs, strikes and slow downs, except for any labour problems of the Party claiming a force majeure event), or court order or injunction; provided that written notice of delay (including anticipated duration of the delay) shall be given by the affected Party to the other Party within two (2) Business Days of the affected Party first becoming aware of such event and the affected Party shall use diligent efforts to end the failure or delay and minimize the effects of such force majeure event. In the event that the force majeure event lasts for fifteen (15) Business Days or longer, either Party shall have the option to terminate this Agreement upon written notice to the other without liability. 19. DISPUTE RESOLUTION (a) Discussions: Each Party agrees to utilize all reasonable efforts to resolve any dispute, whether arising during the term of this Agreement or at any time after the expiration of termination of this Agreement, which touches upon the validity, construction, meaning, performance or effect of this Agreement or the rights and liabilities of the Parties or any matter arising out of or connected with this Agreement, promptly and in an amicable and good faith manner by negotiations between the Parties.

24.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Mediation: Either Party may submit a dispute to mediation by providing written notice to the other Party. In the mediation process, the Parties will try to resolve their differences voluntarily with the aid of a single, impartial mediator, who shall attempt to facilitate negotiations. The mediator shall be selected by agreement of the Parties. If the Parties cannot otherwise agree on a mediator within five (5) Business Days, a single mediator shall be designated by the ADR Institute of Canada, Inc. or any successor organization (ADR) at the request of a Party. Any mediator so designated must not have a conflict of interest with respect to any Party. The mediation shall be conducted as specified by the mediator and agreed upon by the Parties. The Parties agree to discuss their differences in good faith and to attempt, with the assistance of the mediator, to reach an amicable resolution of the dispute. The mediation shall be treated as a settlement discussion and therefore shall be confidential. The mediator may not testify for either Party in any later proceeding relating to the dispute. No recording or transcript shall be made of the mediation proceedings. Each Party shall bear its own costs and legal fees in the mediation. The Parties shall share the fees and expenses of the mediator equally. (c) Arbitration: Subject to Section 19(d), any dispute that has proceeded through mediation established in Section 19(b) without resolution may be submitted to arbitration. Any arbitration conducted pursuant to this Agreement shall take place in the City of Toronto, Ontario. The costs of the arbitration shall be borne equally by the Parties or as may be specified in the arbitrator's decision. The provisions of the Arbitration Act of Ontario, as amended, except as otherwise provided in this Agreement shall govern the arbitration process. The Parties agree to exclude the appeal provisions of the Arbitration Act, as may be amended from time to time, and in particular, section 45 thereof. The determination arising out of the arbitration process shall be final and binding upon the Parties to the arbitration. (d) Exceptions to Arbitration: The following matters shall be excluded from arbitration under this Agreement: (i) any disputes involving third Persons; (ii) breach of confidentiality by either Party; and (iii) intellectual property claims, whether initiated by third Persons or by one of the Parties to this Agreement. 20. MISCELLANEOUS (a) Notice: Every notice or other communication hereunder shall be deemed to have been duly given and made if in writing and if served by personal delivery upon the Party for whom it is intended, if delivered by registered or certified mail, return receipt requested, or by a national courier service, or if sent by fax (receipt of which is confirmed) to the Person at the address set forth below, or such other address as may be designated in writing hereafter, in the same manner, by such Person: To: Ehave To: CHT 277 Lakeshore Road E 1 Scarsdale Road Suite 203 Oakville, Ontario Toronto, Ontario Canada Canada L6J 6J3 M3B 2R2 Attention: Prateek Dwivedi, President & CEO Attention: Scott Woodrow, CEO Any such notification shall be deemed delivered (a) upon receipt, if delivered personally, (b) on the next Business Day, if sent by national courier service for next Business Day delivery or if sent by fax. Any correctly addressed notice or last known address of the other Party that is relied on herein that is refused, unclaimed, or undeliverable because of an act or omission of the Party to be notified as provided herein shall be deemed effective as of the first date that said notice was refused, unclaimed, or deemed undeliverable by the postal authorities by mail, through messenger or commercial express delivery services.

25.

Source: EHAVE, INC., 20-F, 5/15/2019





(b) Modifications: The Parties may modify this Agreement only upon written agreement. (c) Further Assurances: Each Party shall take such action (including, but not limited to, the execution, acknowledgement and delivery of documents) as may reasonably be requested by the other Party for the implementation or continuing performance of this Agreement. (d) Relationship: The Parties are independent contractors and no other relationship is intended. Nothing herein shall be deemed to constitute either Party as an agent, representative or employee of the other Party, or both Parties as joint venturers or partners for any purpose. Neither Party shall act in a manner that expresses or implies a relationship other than that of independent contractor. Each Party shall act solely as an independent contractor and shall not be responsible for the acts or omissions of the other Party. Neither Party will have the authority or right to represent nor obligate the other Party in any way except as expressly authorized by this Agreement. (e) Enurement: This Agreement shall enure to the benefit of and be binding upon each of the Parties hereto and their permitted successors and assigns. (f) No Assignment: Neither this Agreement nor any rights or obligations hereunder shall be assignable by a Party without the prior written consent of the other Party, provided that either Party shall have the right, on notice to but without the other Party's consent, to assign this Agreement and its rights and obligations contained herein, to an affiliate or to a third party who is not a competitor of the other Party in connection with a sale of all or substantially all of the assigning Party's business or assets relating to this Agreement. (g) Counterparts and Facsimile Execution and Delivery: This Agreement may be executed in counterparts, each of which shall be deemed to be an original and both of which together shall constitute one and the same instrument. To evidence its execution of an original counterpart of this Agreement, a Party may send a copy of its original signature on the execution page hereof to the other Party by facsimile transmission or email and such transmission shall constitute delivery of an executed copy of this Agreement to the receiving Party as of the date of receipt thereof by the receiving Party or such other date as may be specified by the sending Party as part of such transmission. (h) Language: It is the Parties desire and agreement that this Agreement and all Exhibits and associated documentation be drafted in English. Les Parties conviennent que la présente convention et tous les documents s'y rattachant, soient rédigés en anglais.

26.

Source: EHAVE, INC., 20-F, 5/15/2019





IN WITNESS WHEREOF, each Party hereto has caused this Agreement to be duly executed as of the date first written above by an officer authorized in that behalf. EHAVE, INC. COMPANION HEALTHCARE TECHNOLOGIES CORP per: /s/ Prateek Dwivedi per: /s/ Scott Woodrow Name: Prateek Dwivedi Name: Scott Woodrow Title: Chief Executive Officer Title: Chief Executive Officer

27.

Source: EHAVE, INC., 20-F, 5/15/2019 
Question: Highlight the parts (if any) of this contract related to Third Party Beneficiary that should be reviewed by a lawyer. Details: Is there a non-contracting party who is a beneficiary to some or all of the clauses in the contract and therefore can enforce its rights against a contracting party?

Output: 31739


Input: Consider Input: [***] = CONFIDENTIAL TREATMENT REQUESTED

SCHEDULE A Product License Schedule FORM  This Product License Schedule is issued pursuant to the Software License, Customization and Maintenance Agreement (the Agreement) executed by and between Bank of America, N.A. (Bank of America) and Cardlytics, (Supplier) and incorporates by reference all of the terms and conditions of the Agreement.

  TERM FOR ORDERING

A. Software

This Schedule constitutes an Order in accordance with the terms of the Agreement.

  B. Payment Schedule for Source Code delivery as outlined in Section 2.7

 •  Beginning three (3) years after the General Services Agreement Effective Date, the Supplier Software version in place one (1) yearfollowing the Service reaching 10,000,000 Users $[***]

 •  The latest commercially available version, or earlier versions at Bank of America's option, of the Supplier Software:

  •  Beginning 3 years after the General Services Agreement Effective Date or one (1) year following the Service reaching 10,000,000 Users, whichever is later, if Supplier has failed to meet either of the Performance Adjustments as outlined in Schedule B of the General Services Agreement for six (6) consecutive months. $[***]

  •  Beginning 3 years after the General Services Agreement Effective Date and one (1) year following the National Launch date and Supplier has met both of the Performance Adjustments as outlined in Schedule B of the General Services Agreement. Bank of America Total Revenue Share minus Supplier Total Revenue share for the preceding twelve (12) months

 •  At any time if Supplier materially breaches either Agreement $[***]

  C. Maintenance Services

No-charge Maintenance Services shall be provided from the Delivery Date through the Warranty Period. The first paid (Initial) Maintenance Term shall commence upon expiration of the Warranty Period and shall continue for twelve (12) months thereafter. Thereafter, the Maintenance Term shall automatically renew for successive period, 12 months, on the terms and conditions of this Agreement unless Bank of America terminates Maintenance Services pursuant to this Agreement. Bank of America may terminate Maintenance Services for convenience at any time in accordance with the Section entitled Termination of the Agreement. If Bank of America terminates the Maintenance Services, Bank of America shall have the right to reinstate the Maintenance Services without paying any reinstatement fee. During the initial Maintenance Term and any renewal term, Maintenance Fees shall be paid in the increments described below under Payment Terms.    Proprietary to Bank of America  Page A-2  vTIP2010

Source: CARDLYTICS, INC., S-1, 1/12/2018





PRODUCTS   LICENSED PROGRAMS:  PROGRAM MATERIALS:  PLATFORM:

The Software consists of the following:  The Program Materials include the following:  The Platform consists of the following:

Cardlytics OPS (Offer Placement System) Version 3.0



Installation Guides Operational Guides



Computer: database servers, application servers and web servers

Operating System: Microsoft.net and SQL 2008

Other Required Components Client side ad serving technology

  PAYMENT TERMS

The Software License and Maintenance will be provided at no charge.    Proprietary to Bank of America  Page A-3  vTIP2010

Source: CARDLYTICS, INC., S-1, 1/12/2018





[***] = CONFIDENTIAL TREATMENT REQUESTED

PAYMENT TERMS

DELIVERY/INSTALLATION DATES   ACCEPTANCE PERIOD  MAINTENANCE PERIOD

WARRANTY PERIOD DURATION

Delivery Date:

TBD

Installation Date:

TBD

The period commencing on the Installation Date and continuing for the number of days specified:

120 days



Notwithstanding anything set forth elsewhere in this Agreement (or below), the Maintenance Period shall be twenty- four (24) hours per day, seven (7) days per week, including Bank of America holidays.

120 days

METHOD OF DELIVERY AND STATE WHERE SOFTWARE AND DOCUMENTATION ARE RECEIVED

The method of delivery and name of the State where Supplier shall deliver and Bank of America shall receive Software and Documentation:

TBD

TRAINING

Supplier shall provide the following training classes pursuant to this Agreement in connection with installation of the first copy of the Software.

Date:

INSTALLATION SUPPORT

In addition to the installation support provided pursuant to the Section entitled Ordering, Delivery and Installation, Supplier shall provide Bank of America the following installation services:

Installation Support will be handled in a separate agreement

NON-MAINTENANCE SERVICES SUPPORT

Support services shall be provided at the Time and Materials rates set forth in the Price List.

RELATIONSHIP MANAGERS

The following shall be the Relationship Managers for the parties:    Bank of America:  Cardlytics:    Brian Woodward  Jason Brooks     Address: [***]  [***]    Proprietary to Bank of America  Page A-4  vTIP2010

Source: CARDLYTICS, INC., S-1, 1/12/2018





SOURCE CODE INSTALLATION SITE

Bank of America shall maintain its copy of the Source Code on the terms of this Agreement at the following address:    Address:  TBD

INSTALLATION SITE

 Address:  TBD

INVOICE ADDRESS(ES)

Licenses:

 N/A         Maintenance:

 N/A          Proprietary to Bank of America  Page A-5  vTIP2010

Source: CARDLYTICS, INC., S-1, 1/12/2018 
Question: Highlight the parts (if any) of this contract related to Warranty Duration that should be reviewed by a lawyer. Details: What is the duration of any  warranty against defects or errors in technology, products, or services  provided under the contract?


Output: 3491