In this task, you're given a passage that represents a legal contract or clause between multiple parties. Your job is to write questions that ask the basic details corresponding to the legal contracts or clauses. Avoid questions that can be answered correctly without actually understanding the paragraph, and which might have multiple answers. The answer to each question should be unambiguous.
--------
Question: Exhibit 6.1

APPLICATION DEVELOPMENT AGREEMENT This Application Development Agreement (the Agreement) is entered into as of March 20, 2020, effective as of March 20, 2020 (the Effective Date) by and between InfinixSoft Global LLC, a Florida Limited Liability Company, with its principal office located at 360 NE 75 St Miami, Suite #127, 33138, Miami, Florida (the Developer) and Clickstream Corporation with its principal office located at 1801 Century Park East Suite 1201 Los Angeles, CA 90067 (the Client) and together with the Developer ( the Parties). RECITALS WHEREAS, the Client is engaged in the business of developing and designing mobile software applications; and WHEREAS, the Developer is engaged in the business of developing and designing application solutions; and WHEREAS, the Client wishes to engage the Developer as an independent contractor for the Client for the purpose of designing the Client's application (the Application) on the terms and conditions set forth below; and WHEREAS, the Developer wishes to design the Application and agrees to do so under the terms and conditions of this Agreement; and WHEREAS, each Party is duly authorized and capable of entering into this Agreement. NOW THEREFORE, in consideration of the above recitals and the mutual promises and benefits contained herein, the Parties hereby agree as follows: 1. PURPOSE. The Client hereby appoints and engages the Developer, and the Developer hereby accepts this appointment, to perform the services described in Exhibit A attached hereto and made a part hereof, in connection with the design of the Application (collectively, the Services). 2. COMPENSATION. The total compensation for the design of the app shall be as set forth in Exhibit A hereto. These payments shall be made in installments according to the schedule set forth in Exhibit A hereto. 3. TERM. This Agreement shall become effective as of the Effective Date and, unless otherwise terminated in accordance with the provisions of Section 4 of this Agreement, will continue until the expiration of the Warranty Period as defined in subsection 9(a) of this Agreement. 4. TERMINATION. (a) Types of Termination. This Agreement may be terminated: 1. By either Party on provision of seven (7) days written notice to the other Party in case of a Force Majeure Event. 2. Client has the unilateral right to cancel this agreement at any time within a 7-day notice period. Further, Developer can only cancel due to lack of payment. Client will have a 30 day right to cure before a cancelation can occur. 3. By either Party for a material breach of any provision of this Agreement by the other Party, if the other Party's material breach is not cured within three (3) days of receipt of written notice thereof. This shall include any delays to the timeline specified in Exhibit A. 4. By the Client at any time and without prior notice, if the Developer is convicted of any crime or offense, fails or refuses to comply with the written policies or reasonable directives of the Client, or is guilty of serious misconduct in connection with performance under this Agreement.

1 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





(b) Responsibilities after Termination. Following the termination of this Agreement for any reason, the Client shall promptly pay the Developer according to the terms of Exhibit A for Services rendered before the effective date of the termination (the Termination Date). The Developer acknowledges and agrees that no other compensation, of any nature or type, shall be payable hereunder following the termination of this Agreement. All intellectual property developed pursuant to this Agreement before the Termination Date shall be delivered to the Client within one day of the Termination Date. 5. RESPONSIBILITIES. (a) Of the Developer. The Developer agrees to do each of the following: 1. Create the Application System as detailed in Exhibit A to this Agreement and extend its best efforts to ensure that the design and functionality of the Application System meets the Client's specifications. 2. Devote as much productive time, energy, and ability to the performance of its duties hereunder as may be necessary to provide the required Services in a timely and productive manner and to the timeframe specified in this agreement. 3. Perform the Services in a workmanlike manner and with professional diligence and skill, as a fully trained, skilled, competent, and experienced personnel. 4. On completion of the Application System, assist the Client in installation of the Application System to its final location, which assistance will include helping the Client with its upload of the finished files to the Client's selected Web-hosting Client and submitting for approval on the Apple Store and Google Play Store. 5. Provide Services and an Application System that are satisfactory and acceptable to the Client and free of defects. 6. Communicate and show with the Client regarding progress it has made with respect to the milestones listed in this agreement. 7. Operate and Maintain the Application System through hosting of games including customer Support 8. Assist the Client in identification and acquisition of corporate sponsors 9. Include internal messaging system whereas users can communicate with each other (b) Of the Client. The Client agrees to do each of the following: 1. Engage the Developer as the creator of its Application System. 2. Provide all assistance and cooperation to the Developer in order to complete the Application System timely and efficiently. 3. Provide initial information and supply all content for the Application System. 4. Provide acceptance testing and certification within one week of deployment of final build

2 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





6. CONFIDENTIAL INFORMATION. The Developer agrees, during the Term and thereafter, to hold in strictest confidence, and not to use, except for the benefit of the Client, or to disclose to any person, firm, or corporation without the prior written authorization of the Client, any Confidential Information of the Client. Confidential Information means any of the Client's proprietary information, technical data, trade secrets, or know-how, including, but not limited to, business plans, research, product plans, products, services, customer lists, markets, software, developments, inventions, processes, formulas, technology, designs, drawings, engineering, hardware configuration information, marketing, finances, or other business information disclosed to the Developer by the Client either directly or indirectly. 7. PARTIES' REPRESENTATIONS AND WARRANTIES. (a) The Parties each represent and warrant as follows: 1. Each Party has full power, authority, and right to perform its obligations under the Agreement. 2. This Agreement is a legal, valid, and binding obligation of each Party, enforceable against it in accordance with its terms (except as may be limited by bankruptcy, insolvency, moratorium, or similar laws affecting creditors' rights generally and equitable remedies). 3. Entering into this Agreement will not violate the charter or bylaws of either Party or any material contract to which that Party is also a party. (b) The Developer hereby represents and warrants as follows: 1. The Developer has the right to control and direct the means, details, manner, and method by which the Services required by this Agreement will be performed. 2. The Developer has the experience and ability to perform the Services required by this Agreement. 3. The Developer has the right to perform the Services required by this Agreement at any place or location, and at such times as the Developer shall determine. 4. The Services shall be performed in accordance with and shall not violate any applicable laws, rules, or regulations, and the Developer shall obtain all permits or permissions required to comply with such laws, rules, or regulations. 5. The Services required by this Agreement shall be performed by the Developer, and the Client shall not be required to hire, supervise, or pay any assistants to help the Developer perform such services. 6. The Developer is responsible for paying all ordinary and necessary expenses of itself or its staff. 7. The Developer shall not develop, maintain or market a similar platform and will not compete with the Client directly or indirectly worldwide. 8. At the time cash online betting is implemented, incorporate and update the approximate 40 algorithms previously developed by Developer for Client. (c) The Client hereby represents and warrants as follows: 1. The Client will make timely payments of amounts earned by the Developer under this Agreement. 2. The Client shall notify the Developer of any changes to its procedures affecting the Developer's obligations under this Agreement at least three days prior to implementing such changes. 3. The Client shall provide such other assistance to the Developer as it deems reasonable and appropriate. 4. Because of the trade secret subject matter of Developer's business, Client agrees that, during the term of this Agreement and for a period of two (2) years thereafter, it will not solicit the services of any of Developer's employees, consultants or suppliers for Client's own benefit or for the benefit of any other person or entity.

3 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





8. APPLICATION REPRESENTATIONS AND WARRANTIES. (a) Performance. The Developer hereby warrants and represents that following delivery of the Application System to the Client (which shall be deeded to occur only on the date the Web Application is uploaded to the AWS for distribution) pursuant to Exhibit A (the Support Period), the Application will be free from programming errors and defects in workmanship and materials, and will conform to the specifications of Exhibit A. If programming errors or other defects are discovered during the Support Period, the Developer shall promptly remedy those errors or defects at its own expense. The developer will fix any bugs that may come up from the original contract after the 90 days warranty has passed. (b) No Disablement. The Developer hereby warrants and represents that the Application System, when delivered or accessed by the Client, will be free from material defects, and from viruses, logic locks, and other disabling devices or codes, and in particular will not contain any virus, Trojan horse, worm, drop-dead devices, trap doors, time bombs, or other software routines or other hardware component that could permit unauthorized access, disable, erase, or otherwise harm the Application System or any software, hardware, or data, cause the Application System or any software or hardware to perform any functions other than those specified in this Agreement, halt, disrupt, or degrade the operation of the Application System or any software or hardware, or perform any other such actions. 9. TIMING AND DELAYS. The Developer recognizes and agrees that failure to deliver the Application in accordance with the delivery schedule detailed in Exhibit A to this Agreement will result in expense and damage to the Client. The Developer shall inform the Client immediately of any anticipated delays in the delivery schedule and of any remedial actions being taken to ensure completion of the Application System according to such schedule. If a delivery date is missed, the Client may, in its sole discretion, declare such delay a material breach of the Agreement under subsection 4(a) and pursue all of its legal and equitable remedies. The Client may not declare a breach, and the Developer cannot be held in breach of this Agreement, of this section if such delay is caused by an action or failure of action of the Client. In such case, the Developer will provide the Client with written notice of the delay and work on the Application System will work until the reason for the delay has been resolved by the Client and written notice of that resolution has been provided to the Developer. 10. NATURE OF RELATIONSHIP. (a) Independent Contractor Status. The Developer agrees to perform the Services hereunder solely as an independent contractor. The Parties agree that nothing in this Agreement shall be construed as creating a joint venture, partnership, franchise, agency, employer/employee, or similar relationship between the Parties, or as authorizing either Party to act as the agent of the other. The Developer is and will remain an independent contractor in its relationship to the Client. The Client shall not be responsible for withholding taxes with respect to the Developer's compensation hereunder. The Developer shall have no claim against the Client hereunder or otherwise for vacation pay, sick leave, retirement benefits, social security, worker's compensation, health or disability benefits, unemployment insurance benefits, or employee benefits of any kind. Nothing in this Agreement shall create any obligation between either Party or a third party. (b) Indemnification of Client by Developer. The Client has entered into this Agreement in reliance on information provided by the Developer, including the Developer's express representation that it is an independent contractor and in compliance with all applicable laws related to work as an independent contractor. If any regulatory body or court of competent jurisdiction finds that the Developer is not an independent contractor and/or is not in compliance with applicable laws related to work as an independent contractor, based on the Developer's own actions, the Developer shall assume full responsibility and liability for all taxes, assessments, and penalties imposed against the Developer and/or the Client resulting from such contrary interpretation, including but not limited to taxes, assessments, and penalties that would have been deducted from the Developer's earnings had the Developer been on the Client's payroll and employed as an employee of the Client.

4 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





11. WORK FOR HIRE. (a) Work for Hire. The Developer expressly acknowledges and agrees that any all proprietary materials prepared by the Developer under this Agreement shall be considered works for hire and the exclusive property of the Client unless otherwise specified. These items shall include, but shall not be limited to, any and all deliverables resulting from the Developer's Services or contemplated by this Agreement, all tangible results and proceeds of the Services, works in progress, records, diagrams, notes, drawings, specifications, schematics, documents, designs, improvements, inventions, discoveries, developments, trademarks,, licenses, trade secrets, customer lists, databases, software, programs, middleware, applications, and solutions conceived, made, or discovered by the Developer, solely or in collaboration with others, during the Term of this Agreement relating in any manner to the Developer's Services. (b) Additional Action to Assign Interest. To the extent such work may not be deemed a work for hire under applicable law, the Developer hereby assigns to the Client all of its right, title, and interest in and to such work. The Developer shall execute and deliver to the Client any instruments of transfer and take such other action that the Client may reasonably request, including, without limitation, executing and filing, at the Client's expense, copyright applications, assignments, and other documents required for the protection of the Client's rights to such materials. (c) Notice of Incorporation of Existing Work. If the Developer intends to integrate or incorporate any work that it previously created into any work product to be created in furtherance of its performance of the Services, the Developer must obtain the Client's prior written approval of such integration or incorporation. If the Client, in its reasonable discretion, consents, the Client is hereby granted an exclusive, worldwide, royalty-free, perpetual, irrevocable license to use, distribute, modify, publish, and otherwise exploit the incorporated items in connection with the work product developed for the Client. 12. RETURN OF PROPERTY. Within three (3) days of the termination of this Agreement, whether by expiration or otherwise, the Developer agrees to return to the Client all Client products, samples, models, or other property and all documents, retaining no copies or notes, relating to the Client's business including, but not limited to, reports, abstracts, lists, correspondence, information, computer files, computer disks, and all other materials and all copies of such material obtained by the Developer during and in connection with its representation of the Client. All files, records, documents, blueprints, specifications, information, letters, notes, media lists, original artwork/creative, notebooks, and similar items relating to the Client's business, whether prepared by the Developer or otherwise coming into its possession, shall remain the Client's exclusive property. 13. INDEMNIFICATION. (a) Of Client by Developer. The Developer shall indemnify and hold harmless the Client and its officers, members, managers, employees, agents, contractors, sub licensees, affiliates, subsidiaries, successors and assigns from and against any and all damages, liabilities, costs, expenses, claims, and/or judgments, including, without limitation, reasonable attorneys' fees and disbursements (collectively, the Claims) that any of them may suffer from or incur and that arise or result primarily from (i) any gross negligence or willful misconduct of the Developer arising from or connected with the Developer's carrying out of its duties under this Agreement, or (ii) the Developer's breach of any of its obligations, agreements, or duties under this Agreement. (b) Of Developer by Client. The Client shall indemnify and hold harmless the Developer from and against all Claims that it may suffer from or incur and that arise or result primarily from (i) the Client's operation of its business, (ii) the Client's breach or alleged breach of, or its failure or alleged failure to perform under, any agreement to which it is a party, or (iii) the Client's breach of any of its obligations, agreements, or duties under this Agreement; provided, however, none of the foregoing result from or arise out of the actions or inactions of the Developer.

5 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





14. INTELLECTUAL PROPERTY. (a) No Intellectual Property Infringement by Developer. The Developer hereby represents and warrants that the use and proposed use of the Application by the Client or any third party does not and shall not infringe, and the Developer has not received any notice, complaint, threat, or claim alleging infringement of, any trademark, copyright, patent, trade secrets, industrial design, or other rights of any third party in the Application, and the use of the Application will not include any activity that may constitute passing off. To the extent the Application infringes on the rights of any such third party, the Developer shall obtain a license or consent from such third party permitting the use of the Application. It is hereby stated, the Application developed under this agreement is the exclusive worldwide sole property of Client. (b) No Intellectual Property Infringement by Client. The Client represents to the Developer and unconditionally guarantees that any elements of text, graphics, photos, designs, trademarks, or other artwork furnished to the Developer for inclusion in the Application are owned by the Client, or that the Client has permission from the rightful owner to use each of these elements, and will hold harmless, protect, indemnify, and defend the Developer and its subcontractors from any liability (including attorneys' fees and court costs), including any claim or suit, threatened or actual, arising from the use of such elements furnished by the Client. (c) Continuing Ownership of Existing Trademarks, Copyrights and Patents. The Developer recognizes the Client's right, title, and interest in and to all service marks, trademarks, trade names , Copyrights and Patents used by the Client and agrees not to engage in any activities or commit any acts, directly or indirectly, that may contest, dispute, or otherwise impair the Client's right, title, and interest therein, nor shall the Developer cause diminishment of value of said trademarks or trade names through any act or representation. The Developer shall not apply for, acquire, or claim any right, title, or interest in or to any such service marks, trademarks, trade names, Copyrights and Patents or others that may be confusingly similar to any of them, through advertising or otherwise. Effective as of the termination of this Agreement, the Developer shall cease to use all of the Client's trademarks, marks, and trade names. (d) The Developer recognizes that the complete Intellectual Property of the project belongs to the Client. The Developer will deliver to the Client all the source code, licenses and other assets used during the process as soon as the work described in this proposal is finished under client acceptation and after receiving the last payment. 15. AMENDMENTS. No amendment, change, or modification of this Agreement shall be valid unless in writing and signed by both Parties. 16. ASSIGNMENT. The Client may assign this Agreement freely, in whole or in part. The Developer may not, without the written consent of the Client, assign, subcontract, or delegate its obligations under this Agreement, except that the Developer may transfer the right to receive any amounts that may be payable to it for its Services under this Agreement, which transfer will be effective only after receipt by the Client of written notice of such assignment or transfer. 17. SUCCESSORS AND ASSIGNS. All references in this Agreement to the Parties shall be deemed to include, as applicable, a reference to their respective successors and assigns. The provisions of this Agreement shall be binding on and shall inure to the benefit of the successors and assigns of the Parties. 18. FORCE MAJEURE. A Party shall be not be considered in breach of or in default under this Agreement on account of, and shall not be liable to the other Party for, any delay or failure to perform its obligations hereunder by reason of fire, earthquake, flood, explosion, strike, riot, war, terrorism, or similar event beyond that Party's reasonable control (each a Force Majeure Event); provided, however, if a Force Majeure Event occurs, the affected Party shall, as soon as practicable:

6 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





(a) notify the other Party of the Force Majeure Event and its impact on performance under this Agreement; and (b) use reasonable efforts to resolve any issues resulting from the Force Majeure Event and perform its obligations hereunder. 19. NO IMPLIED WAIVER. The failure of either Party to insist on strict performance of any covenant or obligation under this Agreement, regardless of the length of time for which such failure continues, shall not be deemed a waiver of such Party's right to demand strict compliance in the future. No consent or waiver, express or implied, to or of any breach or default in the performance of any obligation under this Agreement shall constitute a consent or waiver to or of any other breach or default in the performance of the same or any other obligation. 20. NOTICE. Any notice or other communication provided for herein or given hereunder to a Party hereto shall be in writing and shall be given in person, by overnight courier, or by mail (registered or certified mail, postage prepaid, return-receipt requested) to the respective Parties as follows: If to the Client: Contact: Frank Magliochetti, CEO Company Name: Clickstream Corp. Main Address: 1801 Century Park East Suite 1201 Los Angeles, CA 90067 If to the Developer: Contact: Ivan Saroka, CEO Company Name: InfinixSoft Global LLC Main Address: 360 NE 75th St. Suite #127, 33138, Miami, Florida 21. GOVERNING LAW. This Agreement shall be governed by the laws of the state of Florida. If litigation results from or arises out of this Agreement or the performance thereof, each Party shall be responsible for its own attorneys' fees, court costs, and all other expenses, whether or not taxable by the court as costs. 22. COUNTERPARTS/ELECTRONIC SIGNATURES. This Agreement may be executed in one or more counterparts, each of which shall be deemed an original but all of which shall constitute one and the same instrument. For purposes of this Agreement, use of a facsimile, e-mail, or other electronic medium shall have the same force and effect as an original signature. 23. SEVERABILITY. Whenever possible, each provision of this Agreement will be interpreted in such manner as to be effective and valid under applicable law, but if any provision of this Agreement is held to be invalid, illegal, or unenforceable in any respect under any applicable law or rule in any jurisdiction, such invalidity, illegality, or unenforceability will not affect any other provision or any other jurisdiction, but this Agreement will be reformed, construed, and enforced in such jurisdiction as if such invalid, illegal, or unenforceable provisions had never been contained herein. 24. ENTIRE AGREEMENT. This Agreement constitutes the final, complete, and exclusive statement of the agreement of the Parties with respect to the subject matter hereof and supersedes any and all other prior and contemporaneous agreements and understandings, both written and oral, between the Parties.

7 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





25. HEADINGS. Headings used in this Agreement are provided for convenience only and shall not be used to construe meaning or intent. ********************************************************************************************** EXHIBIT A A. PURPOSE OF APPLICATION SYSTEM. To create a new iOS / Android Native app and a web responsive site to allow users to connect with each other inside a unique social betting platform. The Platform is social trivia, initially sports trivia and other trivia contests leading to peer to peer betting intended for the causal and non- professional betting market. A landing page to promote the product is included as well for desktop and mobile devices. Developer will publish the app in Apple Store / Google Play Store with developer accounts registered to the client. The responsive website will be uploaded and deployed into an AWS Environment also registered to the client. The applications and responsive website will be fed by a Ruby on Rails backend with the according API. The API will be open to be used in other sports betting platforms. The app will be developed under the following considerations: ● Native iOS Swift 5.0 Language with Xcode Development Environment. ● Native JAVA with Android Studio for Android Devices with OS 6.0+ ● Ruby On Rails Backend + PostgreSQL + Rest API ● HTML5 + CSS 3 + Bootstrap Core Platform The Core of Click Stream is a free to play gaming platform that caters untapped market of the causal users that will spend a few seconds to interact with a platform for free in order to win real money. Our primary target is not the sports betters or the fantasy players. We target a more general demographic that is much more general and includes more of the female population. Our games will initially be quick to play quiz type games that allows the user to get involved in around 20 seconds, and then receive results from push notifications. Game types are set up dynamically with live game shows with Hosts 2 - 4 times per month. Because the format doesn't change, we can run games nightly for NBA to NHL, NFL to individual events such as the Oscars, other awards shows, and new sporting events such as Soccer and Nascar. Games and events automated from the backend and launched automatically. Api's Are plugged in to track results in real time, and there is a manual option to allow customs events that can be run through the platform. Business model- What sets our platform apart from other platforms in this untapped casual industry is that we have winners win significant amounts of money via time breakers, timing of inputting answers etc. Competitor platforms pay out an average of a few dollars. Our winners are more top loaded and pay out around $2,500 per the top 5 and $1,000 per the top 10. Initially monetization is based upon sponsors paying out the pots. IE, a pot for a single game will be around $25,000 to the winners and Sponsors will pay around $30,000 to $35,000 to sponsor the event. In return they will get around 30,000-75,000 unique user hits and eyeballs to their product/company.

8 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





Eventually the platform will expand into affiliate sales of products and once the audience has grown large enough, peer to peer betting. Monetization We will initially fund the first month of pots in order to attract enough users to get sponsors. After the first month we will have enough users to begin having sponsors pay the pots. We will then expand to peer to peer betting and advertising. B. SERVICES. The Developer will develop the mobile application based on the Client's specifications, will assist the Client in acquiring corporate sponsors and will operate and maintain the Application System through hosting of games including customer support. The Client will provide The Developer with all necessary information to carry out the development process. C. SPECIFICATIONS. Features for Website & iOS / Android Mobile App for users include: ● Home Screen ● Users Sign in / Sign up ● Profile Creation / Edition with ● Social Networks links ● Add image / Videos ● In App Purchase by each platform convenient method + Stripe.com integration on website. ● Lineup Creation ● SMS/email alert system (when a lineup has to be changed). ● Monetization / Subscription Model ● Mirco social betting ● Peer to Peer betting ● Group betting ● Dynamic Quiz game Engine ● Other dynamic Game Engines ● Homepage with newsfeed, how to play screens, institutional information, Twitter feeds, promotions and other CTAs. ● Historical data with How your lineup did compared to winning lineups. ● Push Notification ● Pop up (Advertiser) ● Rate Us ● Chat ● Block / Delete ● Terms of Use / Privacy Policy ● Analytics integration Web Admin Dashboard features include: ● Statistics to see the data in real-time ● Resolve payment issues ● Users Main Administration ● Disable / Lock Users ● Homepage features administration. ● Confirm Signup ● Forgot Password ● Payment success / receipt ● Payment Failed ● Renew Reminder ● Renew Notice

9 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





Transactional emails ● Welcome Email ● Order Confirmation ● Forgot Password Notes ● UI / UX design is included in the proposal. ● The source code belongs to the client and will be delivered as soon as the project is fully finished. ● Confidentiality: The main concept and idea of the platform are not to be shared by Developer. D. COMPLETION SCHEDULE. The schedule for completion of the Application Development (the Schedule) and the responsibilities under the Agreement is detailed as follows: Mobile / Web App development: 24 weeks + 4 weeks for QA & Details. E. MAINTENANCE AND SUPPORT. The Maintenance & Support is not included in this contract, but we suggest making a plan in the future that includes bug fixing, server monitoring and constant optimization of the apps. 90 days warranty (bugfixing) support is included. F. MILESTONES. ● Week 1 -> UI Design + Logo + Look & Feel ● Week 2-> UI Design - 40% of the UX flow completed ● Week 4 -> UI Design - 75% of the UX flow completed ● Week 6 -> Finished UI Design + Feedback / Technical Documentation ● Week 8 -> Final UI Design - Initial Dev. Process - Backend Development Started ● Week 10 -> Initial Dev. builds with 3 or more screens (hardcoded frontend) for iOS ● Week 12 -> Second Dev. builds with 6 or more screens (hardcoded frontend) for iOS ● Week 14 -> Third Dev. builds with all screens (hardcoded frontend) for iOS / Backend CMS in alpha stage ● Week 16 -> Registration process and Home APIs Integrated in Dev. builds. ● Week 18 ->Other APIs Integrated in Dev. builds. ● Week 20 -> Mobile Apps in Alpha Stage with 70% of the APIs Integrated ● Week 22 -> Mobile Apps in Alpha Stage with 90% of the APIs Integrated ● Week 23 -> Mobile Apps in Beta Stage of the APIs Integrated + Payment Gateway Integration ● Week 24 -> Final RC1 Build uploaded to stores + AWS Production Deployment subject to acceptance testing by client G. PAYMENT SCHEDULE. The total cost for the development of the project is $ 480,000. - Developer has accepted 4,122,394 shares of Clients common stock in exchange for $180,000 worth of services to be provided. The Shares were paid to INFX Development, LLC. (Certificate # 1054) and accepted by Developer as payment on December 30t h, 2019 Client will form subsidiary and register the new business if necessary.

10 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020





The Client agrees to pay to the Developer for the development of the project as listed above, the amount of the other $300,000. - according to the following schedule: ● $30,000. - down payment. ● $30,000.- mid payment (Week 2). ● $30,000.- mid payment (Week 6). ● $30,000.- mid payment (Week 9). ● $30,000.- mid payment Week 12). ● $30,000.- mid payment (Week 16). ● $30,000.- mid payment (Week 20). ● $90,000.- following Client acceptance of the Application, and when RC1 version is delivered and uploaded to stores. By signing below, the Parties agree to comply with all of the requirements contained in this agreement. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the date first above written Clickstream Corp. By: Frank Magliochetti, CLIENT CEO Name: Title: CEO InfinixSoft Global LLC DEVELOPER By: Name: Ivan Alejandro Saroka Title: CEO - Founding Partner 11 │ Page

Source: CLICKSTREAM CORP, 1-A, 3/30/2020

Answer: Highlight the parts (if any) of this contract related to Covenant Not To Sue that should be reviewed by a lawyer. Details: Is a party restricted from contesting the validity of the counterparty’s ownership of intellectual property or otherwise bringing a claim against the counterparty for matters unrelated to the contract?


Question: Exhibit 10.14   SOFTWARE MAINTENANCE AGREEMENT   This Software Maintenance Agreement (the Agreement) is entered into as of October 13, 2016, between Leader Act Ltd HK (LEADER), a Nevada Corporation, (hereinafter referred to as Leader), and EZJR, Inc. a Nevada corporation, (hereinafter referred to as EZJR).   WHEREAS, EZJR currently owns a Customer Relationship Management (CRM) software program as developed by LEADER; and   WHEREAS, upon the purchase of the software EZJR entered into an agreement for LEADER to maintain the software for a period of two years after which LEADER was be paid by EZJR to service and maintain the software; and   WHEREAS, this previous agreement expired on May 28, 2016;   NOW THEREFORE, in consideration of the mutual agreements, representations and warranties in this Agreement, the parties agree as follows:   1. EXTENSION OF SERVICE AGREEMENT. Subject to all other terms and conditions set forth herein, as of the date of this agreement, LEADER maintain the software for an additional five years.   2. COMPENSATION TO LEADER. The compensation to LEADER shall be: 3,000,000 shares of EZJR's unregistered restricted common stock which shall be issuable upon the closing;   3. LEADER' REPRESENTATIONS AND WARRANTIES. LEADER represents and warrants to EZJR as follows:   A. LEADER is a corporation duly organized, validly existing, and in good standing under the laws of the Nevada. Leader has all requisite corporate power and authority to enter into this Agreement and perform its obligations hereunder.   B. The execution, delivery, and performance of this Agreement has been duly authorized and approved by the Board of Directors of LEADER, and this Agreement constitutes a valid and binding Agreement of LEADER in accordance with its terms.   C. LEADER has not employed any broker or finder in connection with the transaction contemplated by this Agreement and has taken no action that would give rise to a valid claim against any party for a brokerage commission, finder's fee, or other like payment.   D. LEADER has not employed any broker or finder in connection with the transactions contemplated by this Agreement, or taken action that would give rise to a valid claim against any party for a brokerage commission, finder's fee, or other like payment.

Source: HER IMPORTS, 8-K/A, 10/18/2016





        F. The execution and delivery of this Agreement by LEADER and the consummation of the contemplated transactions, will not result in the creation or imposition of any valid lien, charge, or encumbrance on any of the Assets, and will not require the authorization, consent, or approval of any third party, including any governmental subdivision or regulatory agency.   G. LEADER has no knowledge of any claim, litigation, proceeding, or investigation pending or threatened against LEADER or its Assets that might result in any material adverse change in the business or condition of the Assets being conveyed under this Agreement.   H. None of the representations or warranties of LEADER contain or will contain any untrue statement of a material fact or omit or will omit or misstate a material fact necessary in order to make statements in this Agreement not misleading. LEADER knows of no fact that has resulted, or will result in a material change in the business, operations, or assets of LEADER.   4. REPRESENTATIONS OF EZJR. EZJR represents and warrants as follows:   A. EZJR is a corporation duly organized, validly existing, and in good standing under the laws of the State of Nevada. EZJR has all requisite corporate power and authority to enter into this Agreement and perform its obligations hereunder.   B. The execution, delivery, and performance of this Agreement has been duly authorized and approved by the Board of Directors of EZJR, and this Agreement constitutes a valid and binding Agreement of EZJR in accordance with its terms.   C. EZJR has not employed any broker or finder in connection with the transaction contemplated by this Agreement and has taken no action that would give rise to a valid claim against any party for a brokerage commission, finder's fee, or other like payment.   D. None of the representations or warranties of EZJR contain or will contain any untrue statement of a material fact or omit or will omit or misstate a material fact necessary in order to make the statements contained herein not misleading.   3. INDEMNIFICATION AND SURVIVAL. All representations and warranties made in this Agreement shall survive the Closing of this Agreement, except that any party to whom a representation or warranty has been made in this Agreement shall be deemed to have waived any misrepresentation or breach of representation or warranty of which such party had knowledge prior to Closing. Any party learning of a misrepresentation or breach of representation or warranty under this Agreement shall immediately give written notice thereof to all other parties to this Agreement. The representations and warranties in this Agreement shall terminate one year from the Closing Date, and such representations or warranties shall thereafter be without force or effect, except any claim with respect to which notice has been given to the party to be charged prior to such expiration date. LEADER hereby agrees to indemnify and hold EZJR, it successors, and assigns harmless from and against any and all damage or deficiency resulting from any material misrepresentation, breach of warranty or covenant, or nonfulfillment of any agreement on the part of LEADER under this Agreement.

Source: HER IMPORTS, 8-K/A, 10/18/2016





        4. GOVERNING LAW. This Agreement and any matters arising out of or related to this Agreement will be governed by the laws of the State of Nevada. If any action is brought among the parties with respect to this Agreement or otherwise, by way of a claim or counterclaim, the parties agree that in any such action, and on all issues, the parties irrevocably waive their right to a trial by jury. Exclusive jurisdiction and venue for any such action shall be the State Courts of Nevada.   5. ENTIRE AGREEMENT. This Agreement contains the entire agreement among the parties, and supersedes all prior agreements, representations and understandings of the parties, relating to the subject matter of this Agreement.   6. FURTHER ACTIONS. Each party agrees that after the delivery of this Agreement it or he will execute and deliver such further documents and do such further acts and things as another party may reasonably request in order to carry out the terms of this Agreement.   7. AMENDMENT. No supplement to or amendment of this Agreement will be binding unless executed in writing by LEADER and EZJR.   8. SUCCESSORS AND ASSIGNS. This Agreement will be binding on, and will inure to the benefit of, the parties and their respective successors and assigns, and shall not confer any rights or remedies on any other Persons.   9. COUNTERPARTS. This Agreement may be executed in one or more counterparts, each of which will be deemed a valid, original agreement, but all of which together will constitute one and the same instrument.   10. SEVERABILITY. If any provision of this Agreement or its application to any Person or circumstances is held to be unenforceable or invalid by any court of competent jurisdiction, its other applications and the remaining provisions of this Agreement will be interpreted so as best reasonably to effect the intent of the parties.   11. ATTORNEYS' FEES. Each party will pay its or his own legal fees and other expenses in connection with the preparation of this Agreement and the sale of Assets in accordance with this Agreement. However, if any legal action or other proceeding is brought for the enforcement of this Agreement, or because or arising out of an alleged dispute, breach, default or misrepresentation in connection with any of the provisions of this Agreement, the prevailing party will be entitled to recover reasonable attorney's fees and other costs incurred in that action or proceeding, in addition to any other relief to which it or he may be entitled.   12. NOTICES. All notices, requests, demands, and other communications required or permitted hereunder will be in writing and will be deemed to have been duly given when delivered by hand, by overnight courier, or fax, or two days after being mailed by certified or registered mail, return receipt requested, with postage prepaid.   13. WAIVERS. Any provision of this Agreement may be waived at anytime by the party entitled to the benefit thereof by a written instrument executed by the party or by a duly authorized officer of the party. No waiver of any of the provisions of this Agreement will be deemed, or will constitute, a waiver of any other provision, whether or not similar, nor will any waiver constitute a continuing waiver.

Source: HER IMPORTS, 8-K/A, 10/18/2016





        SIGNATURES   EZJR, INC.   LEADER ACT LTD HK         By: /s/ Barry Hall   /s/ Aymen Boughanmi   Barry Hall   Aymen Boughanmi   Chief Executive Officer   President

Source: HER IMPORTS, 8-K/A, 10/18/2016





        Exhibit A   Customer Relationship Management System Description   The Customer Relationship Management (CRM) system entails all aspects of interaction that a company has with its customer, whether it is sales or service-related. It also provides a greater understanding of the customer and helps manage customer data and all interaction with the customer. Advantages and features of the CRM are as following:     ● Enhanced customer relationship management including retention tools and fraud prevention.         ● Recurring billing feature that allows for fully automated billing and tools to determine approval and decline rates and automated retries of declines.         ● Profit management tools including affiliate commission tracking, price point testing and indemnification of revenue loss causes.         ● Gateway integration and merchant account load balancing.         ● Improved affiliate management and affiliate fraud detection.         ● Better reporting and performance tracking.

Source: HER IMPORTS, 8-K/A, 10/18/2016







Source: HER IMPORTS, 8-K/A, 10/18/2016

Answer: Highlight the parts (if any) of this contract related to Governing Law that should be reviewed by a lawyer. Details: Which state/country's law governs the interpretation of the contract?


Question: Exhibit 4.14 SERVICE AGREEMENT This Service Agreement (Agreement) is entered into on April. 1st 2019 (Effective Date) by and between: PC Financial Services Private Limited, a India company with an address at Building RZ-2, Pole No.-3, G/F Kapashera, Near HDFC Bank, New Delhi (PC Financial), a registered Non-banking Financial Company (NBFC) in India; and Mobimagic Co., Ltd., a company Incorporated under the laws of the People 's Republic of China with its principal place of business at Room 1110-046, A District, No. 1 Building, No.18 East Road, Zhongguancun, Haidlan District, Beijing City (Mobimagic). PC Financial and Mobimagic are individually referred to herein each as a Party and collectively as the Parties. In consideration of their mutual promises, the Parties hereby agree as follows: 1. DEFINITIONS 1.1 Activity means the offering of small, unsecured loans to businesses and individuals in the Territory by PC Financial. 1.2 Business Data means all end user data and user account details, as well as commercial records, relating to PC Financial operation of the Activity in the Territory 1.3 Confidential Information means non-public information that a Party or Its affiliates (disclosing Party) discloses to the other Party or its affiliates (receiving Party) which is designated as being 'proprietary' or 'confidential' or which by its nature or the circumstances reasonably ought to be treated as confidential. Confidential Information includes the disclosing Party's software end prototypes and information relating to the disclosing Party's business affairs, including business methods, marketing strategies, pricing, competitor Information, product development strategies, and financial results. Confidential Information does not include information which (a) is known by the receiving Party, free of any obligation to keep it confidential; (b) is at the time of disclosure, or thereafter becomes, publicly available through no wrongful act of the receiving Party; (c) Is independently developed by the receiving Party, without relying on or referring to the Confidential Information of disclosing Party; or (d) is approved for release by prior written authorization of the disclosing Party. 1.4 Marks means the trademarks and brand names used by the PC Financial to operate the Activity in the Territory. 1.5 Service Period means April. 1st 2019 through to March 30, 2020. 1.6 Services means the services to be performed by Mobimagic as stated in clause 2.2 of this Agreement in terms of this Agreement during the Service Period. 2. THE SERVICES 2.1 PC Financial hereby engages Mobimagic to provide Services to PC Financial during the Service Period, and Mobimagic hereby accepts such engagement in order to gain the income from the Territory. 1





2.2 Mobimagic will provide the system / platform maintenance services and data processing services to PC Financial. 2.3 where required, Mobimagic may assign its employees to India for short durations to support wont for facilitating the rendering of Services and the estimated presence days of those employees in any case will be less than 183 days in the aggregate in any 12 months. 3. WARRANTIES 3.1 Each Party represents and warrants that it has, and will retain during the Service Period hereof, all right, title and authority to enter into this Agreement, and to perform all of its obligations under this Agreement. 3.2 Mobimagic represents and warrants that, (a) Mobimagic is not subject to any Agreement or duty that would be breached by Mobimagic's entering into or performing Mobimagic's obligations under this Agreement or that is otherwise inconsistent with this Agreement; (b) the Services provided hereunder will not infringe any legal rights or interests of any potential customers or third parties, and will not violate any provision of laws and regulations; (c) the Services will be provided in a good and workmanlike manner with at least the same degree of skill and competence normally practiced by professionals providing the same or similar services: (d) Mobimagic shall not store or retain and shall not be required to store or retain any information belonging to the PC Financial (passed through the Services) pursuant to this Agreement at any time, save and except the metadata or hashed data collected in full compliance with applicable law and PC Financial's privacy policy and solely for the purpose of invoicing .and billing PC Financial; (e) on the Effective Date and during the Service Period of this Agreement it will conduct its business in accordance with applicable law and without violating the rights of any third party. (f) It will not intend to access to the data relating to Indian operations of the PC Financial except for the data passing through Services. (g) neither Mobimagic, nor any Individual holding any direct or indirect Interest in Mobimagic, is listed on the U.S. Specially Designated Nationals (SDN) List or Consolidated Sanction List (ref. https://sanctionssearch.ofac.treas.govn), nor is Mobimagic otherwise associated with any of the listed individuals or organizations; and (h) in connection with performance of the Services In the Territory, as well as its performance of this Agreement, Mobimagic and its affiliates will not violate any provision of the US Foreign Corrupt Practices Act, the UK Bribery Ad., or any anti- corruption related laws in the Territory. 3.3 PC Financial represents and warrants that on the Effective Date and during the Service Period of this Agreement: (a) it will conduct its business in Territory in accordance with applicable law and without violating the rights of any third party; and (b) in connection with the conduct of its business in Territory, as well as its performance of this Agreement, PC Financial and Its affiliates will not violate any provision of the US Foreign Corrupt Practices Act, the UK Bribery Act, or any anti-corruption related laws in the Territory. 2





3.4 Except as set forth in this Section 3, the Parties and their suppliers disclaim all warranties, either express or implied, statutory or otherwise, inducing without limitation warranties of functionality, merchantability, fitness for a particular purpose. 4. RIGHTS AND OBLIGATIONS 4.1 PC Financial shall pay a monthly Fee to Mobimagic in accordance with this Agreement and within the timeline as permitted under the prevailing India regulations. 4.2 PC Financial shall be responsible for acquiring the technical equipment necessary for receiving the Service, and shall also in other respects bear its own costs in the carrying out of any activities relating to its own products and software applications. 4.3 Mobimagic warrants that the Services provided hereunder will not infringe any legal rights and interests of any potential customers and third parties, and will not violate any provision of laws and regulations. The Services it provides pursuant to the Agreement will be provided in a good and workmanlike manner with at least the same degree of skill and competence normally practiced by professionals providing the same or similar services and PC Financial has the right to continuous review and assesses the Services provided by Mobimagic and give its necessary suggestions towards the Services. Mobimagic may take necessary corrective measures of its Services according to PC Financial's requirements. 4.4 PC Financial shall maintain an updated privacy policy and consent driven architecture, to ensure that it has adequate approvals from the concerned persons, entities and/or authorities as required by law to access, collect, store and transmit personal data of any entity using the Services. The Parties hereby agree and confirm, and Mobimagic. warrants, that Mobimagic shall not store or retain and shall not be required to store or retain any information belonging to the PC Financial (passed through the Services) pursuant to this Agreement at any time, save and except the records of transactions just for the purpose of Invoicing and billing the PC Financial. Mobimagic warrants that it will not take any action, or collect any data, which causes a breach of applicable law or PC Financial'& privacy policy and consent driven architecture. Subject to the foregoing as wen as Mobimagic's obligations under this Agreement, Mobimagic shall not in any manner be held or be responsible or liable for any unforeseen contingency, claims, liabilities, demands. losses, damages or expenses arising due to absence of storage or retention of any PC Financial data which shall be the sole responsibility of PC Financial . 4.5 According to this Agreement, the Services provided by the Mobimagic are only for PC Financial's reference, it does not constitute any recommendation or decision. Any judgments, inferences or views made by PC Financial on the basis of the Information provided by the Mobimagic do not represent the positions and opinions of the Mobimagic. PC Financial shall be responsible for data security management and confidentiality responsibilities. According to this agreement, Mobimagic shall not be responsible for the usage and consequences of the data information acquired by PC Financial. 4.6 PC Financial shall not, directly or Indirectly: (a) remove any proprietary notices or labels; (b) make the Services available to any third party without the prior written consent of the Mobimagic, other than the authorized users In furtherance of the Activity; (c) falsely imply any sponsorship or association with Mobimagic; (d) use the Services to send unsolicited communications junk mail, spam, pyramid schemes or other forms of duplicative or unsolicited messages; (e) use the Services to store or transmit any content that infringes upon any person's intellectual property rights (f) use the Services to knowingly post, transmit, upload, link to, send or store any viruses, malware, Trojan horses or any other similar harmful software; or (g) knowingly use the Services in violation of this Agreement. 3





4.7 Data protection. Each Party agrees to comply with all applicable data protection and privacy laws arising from its obligations, if any, under the Agreement and to reasonably co-operate with the other Party in order to allow the other Party to comply with any laws as deemed necessary from time to time. Each Party shall treat all data, information relating to Services, including but not limit to the customer personal data, as confidential. Each party warrants that it shall take appropriate technical and organizational measures against unauthorized or unlawful processing of personal data and against accidental loss or destruction of, or damage to, the personal data of the other party. 4.8 Both Parties acknowledge and confirm that the Reserve Bank of India (hereafter RBI) or persons authorized by it has right to access and inspect the PC Financial's documents, records of Service transactions and other necessary information related to the Services or Activity given to, stored or processed by Mobimagic within a reasonable time. 5. INTELLECTUAL PROPERTY RIGHTS 5.1 Nothing in this Agreement shall be construed as transferring the Intellectual Property Rights of either Party or its suppliers to the other Party. For the avoidance of doubt: (a) all Intellectual Property Rights In and to the Marks and the Business Data shall remain the property of PC Financial or its Affiliates as the case may be. Mobimagic acknowledges that it shall acquire no proprietary rights whatsoever in and to the Marks used in the Activity or the Business Data generated by the Activity, which shall remain the sole and exclusive property of PC Financial and Its Affiliates for their unlimited exploitation and all use and acquired goodwill shall inure to PC Financial and its Affiliates' sole benefit. 6. COMPENSATION AND EXPENSES 6.1 Subject to the terms and conditions of this Agreement. PC Financial shall pay to Mobimagic a fixed service fee in the amount of 970,000 United States Dollars (USD 970,000) for each month (the Fee) within the timeline as permitted under the prevailing India regulations. It is stipulated in this Agreement that Mobimagic will send an invoice to PC Financial on monthly basis according to the progress of the service. After PC Financial confirms that invoice contents are correct, PC Financial shall pay within 45 days after confirming thus. 6.2 The payment is effected by means of bank transfer to the account specified In Mobimagic's invoice. 6.3 The Fee provided is exclusive of Goods and Service Tax (GST) which may be levied under Reverse Charge Mechanism. Any respective taxes for each party will be the responsibility by each party. If law requires that taxes be withheld PC Financial shall (a) deduct those taxes from the Fee; (b) pay the taxes to the proper governmental body; (c) send evidence of the obligation and proof of tax payment to Mobimagic; (d) remit the Fee amount, after deductions and withholding; and (e) cooperate with Mobimagic to obtain refunds of such taxes if there Is any preferential tax treatment available. 6.4 The Fee may be changed by mutual agreement in writing between Mobimagic and PC Financial according to the service content, complexity of services involved or arm's length principles. 4





6.5 In case of any complaint about using the Services as set out in this Agreement PC Financial shall raise the problems within 20 business days after getting Mobimaigc's invoice. Both Parties shall engage in reasonable efforts to negotiate and solve the problems together. If the cause of the difference remains undetermined after the aforesaid efforts of the Parties, an independent third party, (e.g., external auditors) may be employed to give an inspection. The costs arising out of the third- party inspection shall be borne by the Parties according to their respective faults. 7. CONFIDENTIALITY & PUBLICITY Neither Party shall disclose the other Party's Confidential Information to any third party or use Confidential Information for any purpose other than fur the proper fulfillment of this Agreement. Each Party undertakes to safeguard the Confidential Information of the other Party with the same degree of care as it would apply to Its own Confidential Information and, in any case, with no less than reasonable care. Such obligations will survive the expiration of this Agreement for a period of five (5) years. 8. INDEMNIFICATION 8.1 PC Financial shall defend at its own expense and indemnify Mobimagic against any cost, loss or damage arising out of any claim, demand, suit or action (Action) brought against Mobimagic by a third party to the extent that such Action is related to PC Financial's breach of this Agreement. Mobimagic will promptly inform PC Financial in writing of any such Action and will co-operate in the defence and/or settlement of the Action. PC Financial agrees that in negotiating any settlement, it shall act reasonably and shall obtain Mobimagic's prior, written consent which consent shall not be unreasonably withheld. 8.2 Mobimagic shall indemnify and hold harmless PC Financial and its officers, direct0l8 and Affiliates, (PCF Indemnified Parties) against any cost, penalty, loss or damage arising out of or related to the Services, or Mobimagic's breach of this Agreement or applicable law. PC Financial will promptly inform Mobimagic in writing of any such Action and will co-operate in the defence and/or settlement of the Action. Mobimagic agrees that in negotiating any settlement, it shall act reasonably and shall obtain PC Financial's prior, written consent which consent shall not be unreasonably withheld. 8.3 Neither Party shall be liable to the other Party in contract, tort or otherwise, whatever the cause, for any loss of profit, business or goodwill or any indirect, incidental or consequential costs, damages or expenses of any kind, except for such loss attributable to breach of confidentiality. 9. TERM & TERMINATION 9.1 The Agreement shall commence on the Effective Date and continue in effect for the Service Period, unless terminated earlier as provided in this Section. This Agreement is a memorialization of an earlier oral Agreement and shall be deemed to apply for the entire Service Period. The Agreement may be extended or renewed by the Parties in a writing executed by authorized representatives of each of the Parties. 9.2 This Agreement may be terminated by either Party prior to the end of the Service Period if the other Party is in material breach of any tem, or condition of this Agreement and such breach la not remedied for a period of thirty (30) days after the Party in breach has been notified In writing of such breach by the other Party. 9.3 This Agreement terminates automatically, with no further act or action of either Party, if: (a) so required by applicable law or regulations; or (b) a receiver is appointed for a Party or its property, a Party makes an assignment for the benefit of its creditors, goes bankrupt or is liquidated or dissolved. 5





9.4 Upon termination or expiration of this Agreement (i) Each Party shall return to the other Party or destroy (If so authorized in writing by the other Party) any Confidential information in the Party's possession or control, and cause an officer to certify in writing to the other Party that it has done so; (ii) Each Party's rights to be paid and each Party's obligations to pay all amounts due hereunder, as well as Sections 3 through 10 shall survive termination of this Agreement. 10. MISCELLANEOUS 10.1 The Parties to this Agreement are independent contractors. Nothing in this Agreement is intended or should be construed to create an agency, partnership, Joint venture, or employer-employee relationship between PC Financial and Mobimagic. Either Party will represent itself to be an employee or agent of the other Party or enter into any agreement on the other Party's behalf or in the other Party's name. Each Party will retain full control over the manner and means by which it conducts its business and neither Party will be entitled to waive any entitlement to workers' compensation, disability, retirement, insurance, stock options or any other benefits afforded to its employees. 10.2 IN NO EVENT WILL EITHER PARTY BE LIABLE FOR ANY CONSEQUENTIAL, INDIRECT, EXEMPLARY, SPECIAL, OR INCIDENTAL DAMAGES ARISING FROM OR RELATING TO THIS AGREEMENT. NEITHER PARTIES' TOTAL CUMULATIVE LIABILITY IN CONNECTION WITH THIS AGREEMENT, WHETHER IN AGREEMENT OR TORT OR OTHERWISE, WILL NOT EXCEED THE AGGREGATE AMOUNT OF FEES AND EXPENSES OWED BY PC FINANCIAL TO MOBIMAGIC FOR SERVICES PERFORMED UNDER THIS AGREEMENT. 10.3 This Agreement (and any question about its subsistence, effect or termination) is to be interpreted in accordance with the laws of India, save for that body of law which governs the conflict of laws. The courts of New Delhi shall have exclusive jurisdiction to settle any dispute between the Parties whether arising In connection with this agreement or otherwise. In the event of any dispute with respect to the construction, execution and performance of the provisions of this Agreement, such dispute shall be settled by arbitration in accordance with the Arbitration and Conciliation Act, 1996 and rules made thereunder in force as on that date. The arbitration shall be carried out in English language and the venue/seat of arbitration shall be New Delhi. The Arbitration award shall be final and binding on the parties. 10.4 If any provision of this Agreement is, for any reason, held to be Invalid or unenforceable, the other provisions of this Agreement will be unimpaired and the invalid or unenforceable provision will be deemed modified so that it is valid and enforceable to the maximum extent permitted by law. 10.5 This Agreement may not be assigned, delegated, or otherwise transferred, in whole or in part, by operation of law or otherwise, by a Party without the other Party's express prior written consent. Any attempted assignment, delegation, or transfer in violation of the foregoing will be null and void. 10.6 All waivers must be in writing and signed by the Party to be charged. Any waiver or failure to enforce any provision of this Agreement on one occasion will not be deemed a waiver of any other provision or of such provision on any other occasion. 6





10.7 This Agreement is the final, complete, and exclusive agreement of the Parties with respect to the subject matter hereof and supersedes and merges all prior or contemporaneous communications and understandings between the Parties. No modification of or amendment to this Agreement will be effective unless in writing and signed by the Party to be charged. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the Effective Date. PC Financial Services Private Limited Mobimagic Co., Ltd. Signed:/s/ Mars Zhang Signed:/s/ Jiaojiao Liu Name: Mars Zhang Name: Jiaojiao Liu Title: Chief Executive Officer Title: Authorized Signatory 7

Answer:
Highlight the parts (if any) of this contract related to Cap On Liability that should be reviewed by a lawyer. Details: Does the contract include a cap on liability upon the breach of a party’s obligation? This includes time limitation for the counterparty to bring claims or maximum amount for recovery.