In this task, you're given a passage that represents a legal contract or clause between multiple parties, followed by a question that needs to be answered. Based on the paragraph, you must write the index where the answer starts. If multiple answers seem to exist, write the index of the answer that is the most plausible. If multiple indices must be used to answer the question, the output should be a common separated list of indices.

SOFTWARE LICENSE AND MAINTENANCE AGREEMENT     THIS SOFTWARE LICENSE AND MAINTENANCE AGREEMENT (Agreement) is made and entered into as of this 27th day of April  2009 by and between SFG Financial Corp, a/k/a E-Path FX, a Delaware Corporation whose principal address is 575 Madison Avenue, 8th Floor, New  York, NY 10022 (Licensor), and 551 FX IB Associates, LLC a Delaware Limited Liability Company, whose principal address is located at 575 Madison Avenue, 8th Floor, New York, NY 10022 (Licensee).     WHEREAS, Licensor is the owner of a certain proprietary trading software known as the E-Path FX Trading Platform, specifically, and  variations thereof, along with documentation and related information, including the intellectual property rights pertaining thereto: and     WHEREAS, Licensor is the owner of the computer equipment (the Hardware) required for the operation of the Platform that is located  at a single centralized location, specifically at Internap Inc,76 Ninth Avenue, New York, New York10011; and     WHEREAS, Licensee desires to obtain from licensor a Non Exclusive, Non Transferrable license rights and licenses granted herein to the  Platform, for purposes of implementing and marketing an over-the-counter, (OTC) Foreign Currency Exchange Service utilizing the Platform; and     WHEREAS, Licensor shall convey a Non Exclusive license to the Licensee solely for Licensee's use in the field of foreign exchange  transactions only; and     WHEREAS, Licensor is willing to grant such rights, licenses and options under the terms and conditions of this agreement;     NOW THEREFORE, in consideration of the mutual covenants contained herein and other good and valuable consideration, the receipt  and sufficiency of which is hereby acknowledged, the parties hereto, intending to be legally bound, agree as follows:        ARTICLE I  CERTAIN DEFINITIONS     For the purposes of this Agreement:





1.1 AFFILIATE means, in the case of any corporation, partnership, limited liability company or other business or investment entity, a  different business entity or other individual that directly or indirectly, through one or more intermediaries controls, or is controlled by, or  is under common control with the business entity.

1.2 CONFIDENTIAL INFORMATION shall mean, all existing and future information, including but not limited to Software documentation,  Software training and instruction manuals, data, reports, programs, methods, tapes, recorded notes, computer-generated data, tests,  studies and other written documents, computer programs, proprietary trade secrets and know-how, Software, Intellectual Property Rights  and any and all other information embodied in a tangible form relating to and disclosed to the Licensee in connection with this  Agreement, including but not limited to those related to the Licensed Technology. The foregoing items referenced in the preceding  sentence shall be deemed to be confidential within the meaning hereof when, and so long as it is not in possession of the Licensee  prior to the disclosure thereof (except in the event same wrongfully obtained by, or wrongly disclosed to the Licensee); or is not then and  does not become part of the public knowledge and literature through the fault of the Licensee.



















1.3 DERIVATIVE WORK means any additions, modifications, improvements or enhancements based upon or incorporating the Licensed  Technology, such as modifications, enhancements or any other form in which the Licensed Software may be recast, transformed or adapted.

1.4 DOCUMENTATION means documentation developed by Licensor from time to time in printed or computer file format relating to the  installation or use of the Licensed Software.

1.5 FIELD OF USE means, and is limited to, the utilization of the Licensed Technology by the Licensee for the exclusive purpose of  fulfilling Spot FX transactions by transmitting market data and orders. The Field of Use shall not include any functions or applications  not expressly described in the preceding sentence, but shall include functions or applications developed by Licensor to enhance the  performance within the Field of Use.

1.6 INTELLECTUAL PROPERTY RIGHTS means, collectively, all of the following intellectual and similar property rights of Licensor,  whether or not filed, perfected, registered, issued or recorded and whether now or hereafter existing including, but not limited to, all: (i)  patents, patent applications, and patent rights, including any and all continuations, divisions, reissues, reexaminations, or extensions  thereof; (ii) rights associated with works of authorship, including but not limited to copyrights, copyright applications and copyright  registrations. Moral Rights (as defined below) trademarks, trademark applications, service marks, trade dress and mask works; (iii) rights  relating to the protection of trade secrets, know-how and other confidential information including, but not limited to, rights in industrial  property and all associated information and confidential or proprietary information; (iv) industrial design rights; (v) utility models,  inventions, and/or discoveries; (vi) know-how or other data or information, software, databases and all embodiments or fixations thereof; (vii) Licenses, documentations, registrations and franchises, and all additions, improvements and accessions to , and books and records describing or used in connection with, any of the items set forth in the preceding clause and (viii) any rights analogous to those set forth  in the preceding clauses and any other proprietary rights relating to intangible property.

1.7 LICENSED KNOW-HOW means the proprietary know-how and trade secrets related to the Licensed Software and all Intellectual  Property Rights with respect to the Licensed Software.

1.8 LICENSED SOFTWARE means the Platform Software.













      ARTICLE II  LICENSE GRANT AND RESTRICTIONS       I. Licensee acknowledges and agrees that:





1.9 LICENSED TECHNOLOGY means the Licensed Know-How and the Licensed Software, collectively.

1.10 MORAL RIGHTS means and right of paternity or integrity, any right to claim authorship of, to object to or prevent and distortion,  mutilation or modification of, or other derogatory action in relation to, the subject work, whether or not such would be prejudicial to the  author's honor or reputation, to withdraw from circulation or control the publication or distribution of the subject work, or similar right,  existing under judicial or statutory law of any county in the world, or under and treaty, regardless of whether or not such right is  denominated or generally referred to as a moral right.

1.11 PLATFORM SOFTWARE means all Software owned, licensed and/or controlled by Licensor necessary for the Licensee to operate E- Path FX Trading Platform (Platform), which provides real-time consolidation of multiple Electronic Communication Networks (ECN)  markets, exchanges, and other pools of liquidity for Spot FX (collectively the Pools of Liquidity) via proprietary processes and front- end user interface for viewing market data and trading Spot FX.

1.12 SOFTWARE means computer programs and systems, whether embodied in software , firmware or otherwise, including, software  compilations, software, software implementations of algorithms, software tool sets, compilers, and software models and methodologies  (regardless of the stage of development or completion) including any and all: (a) media on which any of the foregoing is recorded; (b)  forms in which any of the foregoing is embodied (whether in Source Code, Object Code, executable code or human readable form); (c)  translation, ported versions and modifications or any of the foregoing. Source Code means fully documented human-readable source  code form of the Software, including programmer's notes and materials and documentation, sufficient to allow a reasonably skilled  programmer to understand the design, logic, structure, functionality, operation and features and to use, operate, maintain, modify,  support and diagnose errors. Object Code means Software in machine-readable form that is substantially or entirely in binary form or  otherwise directly executable by a computer after processing or linking.

i. The Licensed Technology is comprised of Licensor's trade secrets and other proprietary, confidential information; and

ii. Licensee will not sell, lease, lend, transfer, assign, hypothecate, or otherwise distribute the licensed programs to  any third party for use in the field of foreign exchange transactions unless the Licensee receives specific approval  of the Licensor.













   The licensee will not use the Licensed Technology or permit the use of the Licensed Technology for any illegal  purpose, and will use the Licensed Technology only in accordance with the terms of this License Agreement.

   Licensor, specifically and without limiting any of the foregoing assumes neither, responsibility or liability for the  availability, timeliness or accuracy of the system or any equipment, regardless of whether or not the equipment was recommended, selected, is contained for, or is located on the Licensor's premises.     The Licensee has independently evaluated the system, and has concluded that use of the system confers a  significant benefit to the Licensee. Accordingly the Licensee hereby assumes all liabilities and risks associated  with the use of the system and equipment, except for direct damages arising from gross negligence or willful  misconduct of the Licensor.

iii. Licensor hereby, subject to the terms and conditions of this Agreement and provided that Licensee makes  payments to Licensor as required under this Agreement, grants to Licensee a non-exclusive license to utilize  Licensed Technology solely in the Field of Use and subject to the additional restrictions set forth below and otherwise in this License Agreement.

iv. It is hereby acknowledged by Licensor, that Licensee desires to make use of the Licensed Technology to access  consolidated market data and to enter orders for trading Spot FX.

v. The Licensee's rights to access and use the Licensed Technology is limited to Licensor's operating hours, on days  that the foreign exchange markets are open for trading (FX) (Market Day). At the end of the Licensor's  operating hours or each market day the system will automatically transmit cancellation messages for each open  ticket that is processed on the system or on any of the Pools of Liquidity at that time. There is no guarantee that  these cancellations of the open tickets, nor that such tickets will not result in executions outside of the Licensor's  operating hours. The Licensee will be responsible for immediately reporting to the Licensor any apparent failure of  either transmissions or other system failure or delays.

vi. The Licensee will use the Licensed Technology only for (i) receiving market data, and (ii) entering trading tickets in  the ordinary course of the Licensee's business activities.

vii. The Licensee acknowledges and understands neither, the Licensor, nor any of its respective affiliates, employees,  officers or agents shall assume any responsibility or liability for the system's operations, involving the operations  of any equipment, (including but not limited to computer equipment or peripherals, server equipment,  communication equipment and data lines, all such equipment, collectively referred to herein as the Equipment).











   The foregoing shall apply regardless of whether a claim arises in contract, tort, negligence, strict  liability or otherwise.     II. Additional Restrictions. The Licensee expressly agrees and acknowledges that, notwithstanding anything herein to the contrary,  Licensee is not licensed to, and Licensee expressly agrees that it shall not(and shall not permit any third party to);







viii. The Licensee acknowledges and understands that accessing the Licensed Technology triggers and constitutes a  renewed assumption of such liabilities and risk.

i. The Licensee agrees that neither the Licensor, nor any of its respective affiliates, employees, officers,  or agents, shall be liable for any loss, damage, cost or expense, (direct or indirect) except for direct  damages arising from the gross negligence of willful misconduct of the Licensor.

ii. Licensor shall assume no liability, both contingent and otherwise, which may arise out of or be in any  way related to the following; (a) furnishing, performance, maintenance, use of, or inability to use all or  any part of the system, (b) any fault in the delivery or operation of the system, (c) suspension or  termination of the Licensee's ability to use all or part of the system, or any inaccuracies or omissions  in any information or documentation provided, (d) any failure or delay suffered or allegedly suffered  by Licensee in initiating and terminating trades, (e) the termination of all or part of this Licensee  Agreement by the Licensor, (f) the termination or modification of any and all parts of the License.

(a) use the Licensed Technology (all or any portion thereof) other than within the scope of the license granted by Licensor  under this Agreement;

(b) disclose any Licensed Technology to, or permit the use or access of any Licensed Technology by, any third party for any  reason without the prior written consent of Licensor;

(c) sublicense, assign, lease, transfer or distribute any Licensed Technology, or operate and Licensed Technology for  timesharing, rental, outsourcing, or service bureau operations, or to train persons (other than employees of the Licensee on  the use of any Licensed Technology solely in the Field of Use);













   In addition, Licensor acknowledges and agrees that, except to the extent necessary for Licensee to exercise its rights under  the license granted in this Agreement, Licensee is not being granted, and will not hold, any other intellectual property rights  of Licensor whatsoever. Licensee's rights in the Licensed Technology are hereby limited to the license rights expressly  granted to Licensee under this Agreement and all rights not expressly granted to Licensee herein are expressly reserved and  retained by Licensor. Licensee acknowledges that the grant of the license set forth in this Section is a non-exclusive license  and that the Licensor shall have the right to use and to license to other parties the Licensed Technology for any purpose  and in any manner as Licensor may determine in its sole discretion.     Licensee acknowledges and agrees that the restrictions set forth in this Section, constitute a material inducement and  consideration for Licensor's willingness to grant the license set forth herein. Any failure of Licensee to adhere to these restrictions will constitute a material failure of consideration and material breach of this Agreement that will entitle Licensor  to terminate this Agreement and all Licensee's rights and licenses hereunder upon written notice to Licensee in accordance  with the provisions of this Agreement.

(d) create or develop, and/or allow any third party to create or develop, any Derivative Work of any Licensed Technology;

(e) disclose any Licensed Technology to, or permit the use or access of any Licensed Technology by any individuals other  than the employees of the Licensee for use in the Field of Use.

(f) directly or indirectly, reverse engineer, reverse assemble, disassemble or decompile all and/or part of the Licensed  Technology, or otherwise attempt to discover any source code, algorithms, trade secrets or other proprietary rights  embedded in or relating to the Licensed Technology by any means whatsoever (except and solely to the extent that applicable law prohibits reverse engineering restrictions), nor shall it knowingly permit any other individual or corporation,  association, partnership, limited liability Licensee, joint venture, joint stock or other Licensee, business trust, trust,  organization, governmental authority or other entity of any kind to do so.

(g) Modify, alter, improve and/or change in any manner all and/or any portion of the Licensed Technology in any manner  without the prior written consent of Licensor.





   ARTICLE III  OWNERSHIP    Licensee acknowledges that Licensor owns all right, title, and interest in and to the Licensed Technology and all Intellectual Property  Rights therein. Licensee will not delete or in any manner alter the copyright, or other proprietary rights, notices of Licensor appearing on or in the  Licensed Technology as delivered to Licensee. Licensee will not copy or reproduce the Licensed Technology (including Derivative Works of  Licensed Technology), in whole or in part without the prior written consent of Licensor. To the extent Licensee is provided reproduction rights  pursuant to such written consent, Licensee must reproduce on each copy of any Software related to the Licensed Technology, all copyrights,  patent, or trademark notice, and any other proprietary legends that were provided in the originals. In addition, Licensee will use its reasonable  efforts to protect Intellectual Property Rights in the Licensed Technology and will report promptly to Licensor any infringement of such rights of  which the Licensee becomes aware. Licensor reserves the right at its discretion to assert claims against third parties for the infringement or  misappropriation of Licensor's Intellectual; Property Rights in the Licensed Technology and to retain all compensation, damages and other  amount payable to Licensor with regard to such infringement or misappropriation therein.       ARTICLE IV  TERM    I Subject to termination pursuant to this Agreement, the Non Exclusive license granted by Licensor to Licensee shall be for an initial  period of 36 months, commencing from the acceptance date, (the Initial Period). The Agreement may be renewed for an additional period of  seven (7) years at the option of the Licensor. Upon any breach by Licensee of any representation, warranty, covenant and/or obligation  hereunder, the Licensor may immediately terminate this Agreement and prohibit the Licensee's use of any and/or all of the Licensed Technology.  In the event of such immediate termination Licensor shall retain all of it rights under this Agreement and applicable law including but not limited to  the right to receive payments for all trades performed using the Licensed Technology.     II The Initial Period shall be extended by mutual written of the parties within 45 days of the close of the Initial Period.     III Any additional extension of this License Agreement will be by mutual agreement in writing.     ARTICLE V  LICENSEE FEE, TAXES, AND TERM     I As consideration for the Licensee to use the licensed programs and software system as set forth in this agreement, Licensee shall pay to  Licensor the Non Exclusive license fee as set forth below.





   (a) Form of Payment:     Licensee shall remit to Licensor, contemporaneous with the execution of this Agreement, a n  Initial Payment of  $35,000.00 which has previously been advanced by Licensee to the Licensor.     All payments provided for in this Agreement are exclusive of, (and Licensee shall pay) all taxes, customs, duties,  insurance, shipping, and other charges. Payments made to Licensor shall be in United States Dollars.     (b) Taxes:     All taxes in connection with this Agreement including foreign or domestic sales, use, personal property, excise, or other  similar taxes, duties, and charges that may become due as a result of sales of the Platform, however, designated, which charges shall be paid directly by Licensee.



   USER FEES - Non-Exclusive User Fee and Pay Periods

   Charges and Payment Terms



(c) Option

The Licensor shall grant to the Licensee a six month option (the Option) to purchase up to 3,333,333 shares of its  common stock. If the Option is exercised in part or in whole on or before June 30, 2009, the exercise price of the Option  shall be $0.15. However, if the Option is exercised after July 1, 2009, the exercise price of the Option shall be $0.20. The Licensor acknowledges that to date the Licensee has advanced the aggregate sum of $63,309, of which $28,309 shall be  applied against the partial exercise of the Option. Additional sums advanced to SFG, prior to the execution of this  Agreement, and subsequent to the execution of this Agreement shall be detailed in Schedule A and annexed hereto  and will be applied consistent with the terms of the Option granted pursuant to this section.

II. As compensation for the Licensee to use the Licensed Technology during the Initial Period, Licensee shall pay to Licensor, the  following user fees:

Monthly Notional  Volume bands  (US$bn) traded on  Platform by Licensee

Payments to Licensor  Fee rate per US$1million  traded  (for each one-way part  of the trade)

0-10 US$7.50

10-20 US$7.00

20-30 US$6.00

30-50 US$5.50

50+ US$5.00























   The cost of the audit will be borne by Licensor unless a discrepancy of more than five-percent (5%) is discovered, in which  case the cost of the audit shall be borne by Licensee.

i. For the purpose of this Agreement:

(i) Monthly Notional Volume  means the US$ (US Dollar) equivalent of the primary currency traded Client turnover,  provided that US$ (US Dollar) conversion should be made based upon the monthly revaluation rate (last business day) and volume should be rounded to the nearest million; and

(ii) For the avoidance of doubt, if any of the Monthly Notional Volume is reached in one relevant month, the fee rate per  trade applicable to the highest Monthly Notional Volume band reached in that month shall apply to all trades (each  way) in that month; not just to the trades within a particular band. For example, if in any given month the Monthly  Notional volume traded is (US$10.1 billion), the fee rate per (US$1 million trade will be US$7 for the entire amount of  US$10.1 billion.

III. Time of Payment

(a) Each payment for a particular calendar month shall be due no later than the (20th) day of the subsequent calendar month.

(b) The Licensee shall calculate the license fee payable to the Licensor for each month based on the Monthly Notional Volume  bands for that pay period and shall pay the Licensor accordingly. In no event shall the amount payable by the Licensor be  less than the amount recorded by the Licensee as being traded with the Licensed Technology multiplied by the applicable  Fees set forth above.

IV. Record Keeping and Reports

(a) As a condition of Licensee receiving the grant of a license herein, Licensee agrees to maintain reasonable records relating to  all trades conducted through the Licensed Technology and all other uses of the Licensed Technology by the Licensee  under this Agreement. Licensee shall prepare and submit summary quarterly reports to Licensor no later than 20 days  following the last business day of each calendar quarter, which reports must specify a complete record of usage of the  Licensed Technology by the Licensee and shall accompany the payments made to Licensor.

(b) Licensee agrees to allow an independent Certified Public Accountant or other Audit Professional, (selected by mutual  agreement) to audit and analyze appropriate accounting records to ensure compliance with all terms of this Agreement. Any  such audit shall be permitted by Licensee within 30 days of Licensee's receipt of a written request of Licensor.



















   Supplemental Payments will be paid by the Licensee to the Licensor within (10) days of receipt of said payments by the Licensee from third parties

   (a) Simultaneously with the execution hereof, the Licensor shall issue to the Licensee 350,000 shares of its common stock as a bonus.

(b) Rebate Shares. During the period commencing on the Acceptance Date through the thirty six (36th) month anniversary of this  Agreement, the Licensor shall remit to Licensee a series of rebates based upon the amount of Notional Volumes traded on the EPath FX  Trading Platform by Licensee. The computation of the rebates received by Licensee shall be expressed as a fixed percentage (15%) of  Billable Platform Fees paid by Licensee to Licensor. The rebates shall be payable in shares of Licensor's Common Stock; priced at $.25  cents per share. The amount of rebates earned by Licensee shall be calculated for each tranche of 30 Billion of Notional Volume traded in  the EPath FX Platform by Licensee. The amount of shares earned by Licensee shall terminate at the earlier of, the expiration of the term of  this Agreement or the receipt of Six (6,000,000) Million shares of Licensor's common stock by Licensee.    By way of illustration, if the Licensee trades 30 Billion of Notional Volume on the Platform, with a Billable Platform Fee of $279,000. The  rebate to Licensee will be calculated as follows:  Rebate = 15% of $279,000 = $41,850;  Shares of Licensor representing $41,850/$.25 = 167,400 shares of Licensor.

V. Enhancements: Supplemental Payments

I. During the term of the non-exclusive license agreement, Licensor shall receive from Licensee one third (33%) of the gross  amounts earned by the Licensee from third parties applicable to the following areas of the Licensed Technology usage (if any),  (Supplemental Payments):

(a) Clearing fees

(b) Banking Rebates (give-up fees)

(c) Processing of half pips

(d) Swap rates (swap interest rate differential)

(e) Currency spreads

II. Shares





  ARTICLE VI  SUB LICENSE AGREEMENT        Licensee agrees it shall not exchange, lease, sublease, distribute, assign, sell or otherwise transfer in any manner any right and/or interest  incident to the License Technology to any third party under any circumstances, without the prior written consent of the Licensor.          ARTICLE VII  TECHNICAL SUPPORT SERVICES       (a) The Licensor shall provide Technical Support Services relating to the maintenance and support of the Software and the Licensee shall pay  the Licensor $2,500 per month for such Technical Support Services.     (b) The Licensee may request that the Licensor performs further development and customization work for creating a unique client front end  and other enhancements to the Platform Software after the effective date. In the event the Licensee desires such services, the Licensee must agree  in writing to a price and the terms for such services based upon the scope of the work requested by Licensee. Until such an agreement is entered  into in writing, the Licensor shall have no obligation to perform such work.     (c) The parties agree that (except for the customization work) (above) all future enhancements to the Software, including any new Revisions,  Versions, updates to, or any other non-customized development work regarding the Software (which the Licensee may accept or decline) shall be  provided to the Licensee during the term of this Agreement at no additional cost.     (d) Except for the Charges set forth above, there shall be no additional fees payable by the Licensee to the Licensor for technical support  services pursuant to this Agreement, unless the parties agree to the contrary in writing.     (e) Licensee and Licensor Responsibilities





i. The Licensor shall provide customer support to Licensee on terms and conditions set forth herein below.

ii. The Licensee agrees to notify the Licensor in writing (including by email) or telephone promptly following the  discovery of any Error. Further, upon discovery of such an Error, Licensee agrees, if requested by the Licensor, to  submit to the Licensor a list of output and any other data that the Licensor may reasonably require to reproduce the  Error (to the extent reasonably available to the Licensee) and the operating conditions under which the Error occurred  or was discovered.









   (f) Error Corrections. During the term of this Agreement, the Licensor shall use commercially reasonable efforts to provide Error  Corrections for Errors in the Software reported by Licensee to the Licensor.     (g) Revisions. During the term of this Agreement, the Licensor shall make available to Licensee any Revisions of the Software or  Documentation at no extra charge, subject to limitations explicitly set forth in this Agreement. The Licensor will make such available to the  Licensee when the Licensor makes such Revisions generally available to its other licensees.     (h) Limitations. The Licensor shall have no obligation under this Agreement to make any modifications, Revisions, or Error Corrections,  other than those required to conform to the requirements of the Specifications and this Agreement. Notwithstanding the foregoing, the Licensor  shall have no obligation under this Agreement to correct Errors which result from the breach by Licensee of this Agreement, or which cannot be  remedied due to any modifications of the Software made by Licensee or any third party without authorization from the Licensor. If the Licensor  agrees to remedy any errors or problems not covered by the terms of this Agreement, Licensee shall pay the Licensor for all such work performed  at the Licensor's then-current standard rates. Licensee acknowledges that the Licensor is under no obligation to perform services with respect to  any hardware or any software which is not the Software.        ARTICLE VIII

CONTACT INFORMATION





Licensor Information:







iii. If required by the Licensee, the Licensor product managers and engineers will host free Web-based training seminars  covering a variety of topics to facilitate the use of the Software. These seminars will be broadcast on a periodic basis,  provided, however, that the Licensor is under no obligation to provide them on any specific schedule.

iv. Any software, modules, or other methods of communication developed by the Licensor in performing duties under this  Agreement shall be kept secure from access by the unauthorized third parties. Any failure of such security shall be  deemed, notwithstanding anything to the contrary, a failure of the Primary Function of the Software.

Account Manager: Michael C. Caska  Telephone: 917-226-9630  Fax: 646-607-9711  E-mail: mcaska@caskaco.com

Billing: Michael C. Caska  Telephone: 917-226-9630  Fax: 646-607-9711  E-mail: mcaska@caskaco.com

Tech Support: Michael C. Caska  Telephone: 917-226-9630  Fax: 646-607-9711  E-mail: mcaska@caskaco.com

Written Notices: SFG Financial Corporation

575 Madison Avenue, 8th Floor,

New York, NY 10022  Att: Michael C. Caska







Licensee Information:









   ARTICLE VIX

WARRANTY DISCLAIMER



THE LICENSED TECHNOLOGY IS PROVIDED ON AN AS IS BASIS WITHOUT WARRANTY OF ANY KIND AND LICENSOR HEREBY

DISCLAIMS ALL WARRANTIES CONCERNING THE LICENSED TECHNOLOGY, WHETHER EXPRESS OR IMPLIED, INCLUDING, WITHOUT

LIMITATION, ANY IMPLIED WARRANTIES OF MERCHANTABILITY, NON-INFRINGEMENT, FITNESS FOR PARTICULAR PURPOSE ,

COMPLETENESS, USE, ACCURACY AND/OR TITLE. LICENSOR DOES NOT WARRANT THAT THE LICENSED TECHNOLOGY IS ERROR-

FREE OR THAT IT WILL MEET LICENSEE'S REQUIREMENTS OR THAT THE OPERATION OF THE LICENSED TECHNOLOGY WILL BE

UNINTERRUPTED,TIMELY SECURE OR ERROR-FREE, OR THAT ERRORS IN THE LICENSED TECHNOLOGY OR NONCONFORMITY TO ITS

DOCUMENTATION CAN OR WILL BE CORRECTED.



Account Manager: Name: Fred Miller  Telephone 212-605-0200  Fax: 212-605-0222  E-mail:_____________________________

Billing: Name: Fred Miller  Telephone 212-605-0200  Fax: 212-605-0222  E-mail:_____________________________

Written Notices: 551 FX IB Associates LLC

575 Madison Avenue, 8th Floor,

New York, NY 10022  Att: Fred Miller





   ARTICLE X

CONFIDENTIAL INFORMATION/NON SOLICITATION

   (a) NONDISCLOSURE. The Licensee shall not disclose, publish, or disseminate the Confidential Information to anyone other than the  Licensee's employees with a need to know and who have agreed in writing to be bound by the confidentiality provisions of this Section, or as may  be required by legal process. The Licensee agrees to use the same degree of care with respect to the Confidential Information that it takes to hold  in confidence its own most valuable proprietary information, but not less than reasonable care, to prevent any unauthorized use, disclosure, publication, or dissemination of the Confidential Information. The Licensee agrees to accept and use the Confidential Information only for the  purpose of carrying out its authorized activities under this Agreement. In the event the Licensee is required to disclose the Confidential  Information by an order of a court or governmental agency, then the Licensee shall first give written notice to Licensor to allow Licensor to make a  reasonable effort to obtain a protective order or other confidential treatment for the Confidential Information.     (b) NON SOLICITATION. During the Term of this Agreement and during the three year period after the expiration or termination of this  Agreement, the Licensee will not solicit any person employed by Licensor and/or its Affiliates to leave his or her employment with Licensor. For  purpose of this Article the term Solicit means any affirmative recruitment specifically aimed at one or more individuals identified by name, title or  affiliation, but shall not mean generally advertising job openings or any activities that constitute follow-up to individuals who respond to job  opening advertisements or who voluntarily initiate employment inquiries.        ARTICLE XI  INJUNCTIVE RELIEF    Licensee acknowledges that (i) any breach of its obligations under this Agreement with respect to the Licensed Technology, the  Licensed Know-How Rights, , the disclosure of Confidential Information and/or the Non Solicitation of Licensor Employees; (ii) any failure by  Licensee to use Licensed Technology strictly in accordance with the license rights granted to Licensee under this Agreement and/or (iii) any breach of its obligations under the additional restrictions contained in this Agreement, will cause Licensor irreparable injury for which there are inadequate remedies at law, and therefore, Licensor will be entitled to equitable relief without the posting of any bond or indemnity (including but  not limited to injunctive relief and the remedy of specific performance) in addition to all other rights and remedies provided by this Agreement or  available at law.





   ARTICLE XII  INDEMNITY    Licensee will be solely responsible for any commercial or legal liability that may arise as a result of Licensee's exercise of any of the  license rights granted by Licensor to Licensee under this Agreement, and Licensee shall defend, indemnify, and hold Licensor harmless from and  against any and all suits, claims, proceedings, judgments, awards, damages, loss, liability, cost and expenses (including without limitation  reasonable attorney's fees and other related costs) that are incurred or suffered by Licensor or any of its affiliates, directors, officers, employees, or  agents to the extent they arise or result, directly or indirectly, from (i) Licensee's exercise of any license or other rights granted to Licensee under  this Agreement; (ii) the conduct of Licensee's business directly or through any affiliate of Licensee and/or (iii) the breach by the License of any representation, warranty, obligation, restriction, term and/or covenant under this Agreement.

   ARTICLE XIII  EXCLUSION OF DAMAGES; LIMITATION OF LIABILITY       (a) IN NO EVENT SHALL LICENSOR BE LIABLE TO LICENSEE OR TO ANY THIRD PARTY FOR ANY SPECIAL, INDIRECT,  INCIDENTAL OR CONSEQUENTIAL DAMAGES (INCLUDING WITHOUT LIMITATION LOSS OF USE, DATA, BUSINESS OR PROFITS)  ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT OR THE USE, OPERATION OR PERFORMANCE OF ANY OF THE  LICENSED TECHNOLOGY, WHETHER SUCH LIABILITY ARISES FROM ANY CLAIM BASED UPON CONTRACT, WARRANTY, TORT  (INCLUDING NEGLIGENCE), PRODUCT LIABILITY BREACH OR FAILURE OF EXPRESS OR IMPLIED WARRANTY OR CONDITION,  MISREPRESENTATION OR OTHERWISE, AND WHETHER OR NOT LICENSORHAS BEEN ADVISED OF THE POSSIBILITY OF SUCH LOSS  OR DAMAGE (INCLUDING, BUT NOT LIMITED TO, CLAIMS FOR LOSS OF DATA, GOODWILL, USE OF MONEY OR USE OF THE LICENSED TECHNOLOGY, INTERRUPTION IN USE OR AVAILABILITY OF DATA, STOPPAGE OF OTHER WORK OR IMPAIRMENT OR OTHER ASSETS), ARISING OUT OF BREACH OR FAILURE OF EXPRESS OR IMPLIED WARRANTY OR CONDITION, BREACH OF CONTRACT,  MISREPRESENTATION, NEGLIGENCE, STRICT LIABILITY IN TORT, OR OTHERWISE     UNDER NO CIRCUMSTANCE SHALL LICENSOR BE LIABLE FOR ANY ACTIONS, CLAIMS OR THE LIKE BY LICENSEE OR ANY THIRD  PARTY THAT THE USE OF THE LICENSED TECHNOLOGY HAS RESULTED, RESULTS OR MAY RESULT IN ANY INFRINGEMENT,  DEPRIVATION OR VIOLATION OF THE INTELLECTUAL PROPERTY, CONSTITUTIONAL, STATUTORY, CONTRACTUAL, COMMON LAW  OR OTHER RIGHTS OF ANY PERSON     (b) IN NO EVENT SHALL LICENSOR'S AGGREGATE CUMULATIVE TOTAL LIABILITY UNDER THIS AGREEMENT EXCEED ONE  HALF OF THE AMOUNT PAID BY THE LICENSEE TO Licensor HEREUNDER.     (c) THIS SECTION IS A MATERIAL INDUCEMENT TO AND CONDITION FOR LICENSOR ENTERING INTO THIS AGREEMENT.





   ARTICLE XIX  INSOLVENCY    Either party shall have the right to terminate this Agreement immediately upon notice to the other party if the other party: (a) becomes the  subject of a voluntary petition in bankruptcy or any voluntary proceeding relating to insolvency, receivership, liquidation, or composition for the  benefit of creditors; or (b) becomes the subject of an involuntary petition in bankruptcy or any involuntary proceeding relating to insolvency,  receivership, liquidation, or composition for the benefit of creditors, if such petition or proceeding is not dismissed within sixty (60) days of filing.     ARTICLE XX  CERTAIN OTHER EVENTS OF TERMINATION    (a) Upon the occurrence of any Change of Control (as defined below) this Agreement and all Licensee's rights and licenses hereunder  shall automatically terminate unless, prior to the occurrence of such Change of Control, Licensor has consented to such Change of Control in a  writing executed by an officer of Licensor; provided that Licensor will not unreasonably withhold its consent to the consummation of a Change of  Control. For purposes of the preceding sentence, Licensor will be deemed to have reasonably withheld its consent to a Change of Control if any  person or entity who would acquire direct or indirect control (as defined below) of Licensee pursuant to such Change of Control then conducts a  business that is directly or indirectly competitive with a business then conducted by Licensor or any of its Affiliates and/or Licensor reasonably believes that Licensor's interests will be adversely effected by the continuing of this Agreement upon such a Change in Control. As used herein,  the term CHANGE OF CONTROL means: (i) a transaction or series of related transactions that results in the sale or other disposition of all or substantially all of Licensee's assets; or (ii) a merger or consolidation in which Licensee is not the surviving corporation or in which, if Licensee is  the surviving corporation, the shareholders of Licensee immediately prior to the consummation of such merger or consolidation do not,  immediately after consummation of such merger or consolidation, own stock or other securities of Licensee that possess a majority of the voting  power of all Licensee's outstanding stock and other securities and the power to elect a majority of the members of Licensee's board of directors; or  (iii) a transaction or series of related transactions (which may include without limitation a tender offer for Licensee's stock or the issuance, sale or  exchange of stock of Licensee) if the shareholders of Licensee immediately prior to the initial such transaction do not, immediately after  consummation of such transaction or any of such related transactions, own stock or other securities of Licensee that possess a majority of the  voting power of all Licensee's outstanding stock and other securities and the power to elect a majority of the members of Licensee's board of  directors. As used herein, the term CONTROL (including, with correlative meanings, the terms, CONTROLS CONTROLLING,  CONTROLLED BY or UNDER COMMON CONTROL WITH) with respect to a designated person means the possession, directly or indirectly,  of the power to vote a majority of the securities having voting power for the election of directors (or other persons acting in similar capacities) of  such person or otherwise to direct or cause the direction of the management and policies of such person, whether through the ownership of voting  securities, by contract or otherwise.     (b) In the event Licensee winds up, dissolves or otherwise ceases doing business, Licensor shall be entitled to terminate this Agreement  immediately upon written notice to Licensee.





   ARTICLE XXI  EFFECT OF TERMINATION    Upon termination of this Agreement: for any reason (a) the rights and licenses granted to Licensee pursuant to this Agreement will  automatically terminate, and (b) Licensee shall, within five (5) days, ship to Licensor all Licensed Technology, API's Documentation with respect  to the Licensed Technology and other Confidential Information in Licensee's possession or control, and an officer of Licensee shall certify in  writing that Licensee as complied with the provisions of this Section. All of the Licensor's rights under this Agreement shall survive termination of  this Agreement.



   ARTICLE XXII  RIGHT OF FIRST REFUSAL    During the term of this Agreement, the Licensor shall have the right (the Right of First Refusal), for a period (the Exercise Period)  expiring at 11:59 PM (Eastern Time) on the fifth (5th) business day after the giving of written notice by the Licensee that it has received a bonafide  offer from a third party to (ii) purchase all or substantially all of the assets of Licensee; or (ii) to engage in a merger or consolidation in which  Licensee is not the surviving corporation or in which, if Licensee is the surviving corporation, the owners of Licensee immediately prior to the  consummation of such merger or consolidation do not, immediately after consummation of such merger or consolidation, own stock or other  securities of Licensee that possess a majority of the voting power of all Licensee's outstanding stock and other securities and the power to elect a  majority of the members of Licensee's board of directors.

   In the event the Licensor declines or fails to exercise in full the Right of First Refusal before the expiration of the Exercise Period, the

Licensee shall have the right to consummate the transaction with the third party.

   ARTICLE XXIII  NON EXCLUSIVE REMEDY    Termination of this Agreement by either party will be a nonexclusive remedy for breach and will be without prejudice to any other right or  remedy of such party.    NO DAMAGES FOR TERMINATION. NEITHER PARTY WILL BE LIABLE TO THE OTHER FOR DAMAGES OF ANY KIND, INCLUDING  WITHOUT LIMITATION INCIDENTAL OR CONSEQUENTIAL DAMAGES, DAMAGES FOR THE LOSS OF GOODWILL, PROSPECTIVE  PROFITS OR ANTICIPATED INCOME, OR DAMAGES RESULTING FROM ANY EXPENDITURES, INVESTMENTS, LEASES OR  COMMITMENTS MADE BY EITHER PARTY ON ACCOUNT OF THE TERMINATION OR EXPIRATION OF THIS AGREEMENT IN ACCORDANCE WITH ITS TERMS.





  ARTICLE XXIV

GENERAL PROVISIONS

   (a) GOVERNING LAW. The parties agree that it is to their mutual benefit that their respective rights and obligations under this Agreement  are guided by, and their disputes hereunder are determined in accordance with, a well developed body of law. Accordingly, the parties agree that  the validity, interpretation and legal effect of this Agreement shall be governed by the internal laws of the State of New York, U.S.A., applicable to  contracts entered in and performed entirely within the State of New York, U.S.A. without regard to any conflict of law principles. The parties agree  that any legal suit, action or proceeding arising out of or relating to this Agreement must be instituted in the City of New York, State of New York,  and the parties each (i) irrevocably submits to the exclusive jurisdiction of the United States District Court for the Southern District of New York, or  any court of the State of New York, and (ii) waives any objection to the venue of any such suit, action or proceeding and any claim relating to  forum non conveniens. In any such suit, action, or proceeding, any summons, order to show cause, writ, judgment, decree or other process may be  delivered to the parties outside the State of New York or outside the United States and when so delivered, such party shall be subject to the  jurisdiction of such court, and amenable to the process so delivered as though the same had been served within the State of New York but outside  the county in which such suit, action or proceeding is pending.    (b) COMPLIANCE WITH LAWS. Licensee agrees to comply in all material respects with all applicable laws, rules, and regulations in connection  with its activities under this Agreement, including without limitation, any applicable export controls imposed by the U.S. Export Administration Act  of 1978, as amended (the ACT) and the regulations promulgated under the Act.    (c) ASSIGNMENT. Licensee may not assign this Agreement or assign, sublicense and/or transfer in any manner its license rights hereunder in  whole or in part without Licensor's prior written consent. Any attempt to assign this Agreement or assign, sublicense and/or transfer in any  manner Licensee's license rights hereunder without such consent will be void and of no effect. For purposes of this Agreement, any Change of  Control (as defined in Section 13.4(a)) shall be governed by the provisions of the section entitled Change Of Control and not the provisions of this  Section Subject to the terms of this Section, this Agreement will bind and inure to the benefit of the parties and their respective successors and  permitted assigns.    (d) ATTORNEYS' FEES. In the event that any action or proceeding is brought in connection with this Agreement, the prevailing party shall be  entitled to recover its costs and reasonable attorneys' fees following a final judgment.    (e) SEVERABILITY. If for any reason a court of competent jurisdiction finds any provision of this Agreement invalid or unenforceable, then that  provision of the Agreement will not be voided, but rather will be enforced to the maximum extent legally permissible and the other provisions of  this Agreement will remain in full force and effect.





  (f) INDEPENDENT CONTRACTOR. The parties to this Agreement are independent contractors and this Agreement will not establish any  relationship of partnership, joint venture, employment, franchise, or agency between the parties. Neither party will have the power to bind the  other or incur obligations on the other's behalf without the other's prior written consent.    (g) NOTICES. All notices required or permitted under this Agreement will be in writing and delivered by confirmed facsimile transmission,  by courier or overnight delivery service, or by certified mail, and in each instance will be deemed given upon receipt. All communications to a party  will be sent to the address of the party set forth in the preamble above or to such other address as may be specified by such party to the other in  accordance with the Section called Contact Information. Either party may change its address for notices under this Agreement by giving written  notice to the other party by the means specified in this Section.    (h) COUNTERPARTS. This Agreement may be executed in counterparts, each of which will be deemed an original, but both of which  together will constitute one and the same instrument.    (e) ENTIRE AGREEMENT. This Agreement, constitutes the complete and exclusive agreement between the parties with respect to the  subject matter hereof, superseding and replacing any and all prior and contemporaneous agreements, communications, and understandings (both  written and oral) regarding such subject matter.    (h) MODIFICATION. No modification to this Agreement, nor any waiver of any rights, shall be effective unless consented to in writing  and the waiver of any breach or default shall not constitute a waiver of any other right or of any subsequent breach or default.    (i) FORCE MAJEURE. Except for the obligations to make payments hereunder, each Party shall be relieved of the obligations hereunder to  the extent that performance is delayed or prevented by any cause beyond its reasonable control, including without limitation, acts of God, public  enemies, war, civil disorder, fire, flood, explosion, labor disputes or strikes or any acts or orders of any governmental authority.    (j) CONSTRUCTION. The parties agree that no ambiguity (if any) found in this Agreement shall be resolved against any party by virtue  of its participation in the drafting of this Agreement.    (k) REPRESENTATION BY COUNSEL. Each party acknowledges that it has had the opportunity to be represented by separate  independent counsel in the negotiation of this Agreement, that any such respective attorneys were of its own choosing, that each authorized  representative has read this Agreement and that it understands its meaning and legal consequences to each party. Each Party warrants and  represents that it has consulted with its attorney of choice, or voluntarily chose not to do so, concerning the execution, the meaning and the import of this Agreement, and has read this Agreement and fully understands the terms hereof as signified by its signature below, and is executing  the same of its own free will for the purposes and consideration herein expressed. Each Party warrants and represents that it has had sufficient time  to consider whether to enter into this Agreement and that it is relying solely on its own judgment and the advice of its own counsel, if any, in  deciding to execute this Agreement. Each Party warrants and represents that it has read this Agreement in its entirety and has consulted with its  attorney, if any concerning the execution of this Agreement. If any or all Parties have chosen not to seek counsel, said party or parties hereby  acknowledge that it or they refrained from seeking counsel entirely of its or their own volition and with full knowledge of the consequences of  such a decision.





     IN WITNESS WHEREOF, the parties have caused this Agreement to be executed as of the Effective Date by their duly authorized  representatives.









SFG FINANCIAL CORP. 551 FX IB ASSOCIATES LLC

By: /s/ Michael C. Caska By: /s/ Fred Miller

Name: Michael C. Caska Fred Miller

Title: Chief Executive Officer Title: Member Manager 
Question: Highlight the parts (if any) of this contract related to Cap On Liability that should be reviewed by a lawyer. Details: Does the contract include a cap on liability upon the breach of a party’s obligation? This includes time limitation for the counterparty to bring claims or maximum amount for recovery.
12451

1

                   EXCLUSIVE DISTRIBUTOR AGREEMENT

     EXCLUSIVE DISTRIBUTOR AGREEMENT (Agreement) dated as April 15, 1994 by and between IMRS OPERATIONS INC. d/b/a IMRS INC., a Delaware corporation with its principal place of business at 777 Long Ridge Road, Stamford, Connecticut 06902, U.S.A. (hereinafter referred to as Developer) and Delteq Pte Ltd, a Singapore company (and a subsidiary of Wuthelam Industries (S) Pte LTD) with its principal place of business at 215 Henderson Road, #101-03 Henderson Industrial Park, Singapore 0315 (hereinafter referred to as Distributor).

     WHEREAS, Developer has developed certain computer programs and related documentation more particularly described in Schedule A attached hereto (the Products) and desires to grant distributor the right to market and distribute the Products in Singapore, Malaysia, Indonesia, Thailand, and Brunei (the Territory); and

     WHEREAS, Distributor is in the business of marketing and distributing computer-related products and desires to have Developer grant to it the right to market and distribute the Products in the Territory.

     NOW, THEREFORE, in consideration of the mutual promises set forth herein, and for other good and valuable consideration, the receipt and sufficiency whereof are hereby acknowledged, the parties hereto agree as follows:

1.   LICENSE

     1.1  Exclusive Distribution License.              ------------------------------

     Upon the terms and subject to the conditions of this Agreement, Developer hereby grants to Distributor an exclusive, non-transferable fight and license to market and distribute the Products in the Territory. Distributor shall distribute the Products to existing and new customers of Distributor located in the Territory (the End-Users) who enter into an End-User License Agreement (as hereinafter defined). The Products shall be in executable object code form only and Distributor shall have no fight to the source code of such Products. The Products distributed to End-Users shall be in executable object code form only. Distributor shall not itself, nor allow others to modify, translate, decompile, nor create or attempt to create, by reverse engineering or otherwise, the source code from the object code of the Products supplied hereunder, or adapt the Products in any way or for use to create a derivative work. Should Distributor wish to create such a derivative work, Distributor must first seek and obtain express written permission to do so from the Developer and Developer may withold such permission at its sole discretion. Distributor may not, and may not permit End-Users to, use, reproduce, siblicense, distribute or dispose of the Products, in whole or in part, except as expressly permitted under this Agreement.

                                   1

2

     1.2  The Territory.              -------------

     Distributor may market and distribute the Products solely within the Territory. Distributor shall not have the right to establish third-party agreements for the license, sale, installation and/or support of the Products in the Territory or elsewhere, without the prior written approval of Developer, which approval may be withheld for any reason.

     1.3  License of the Products to End-Users; Other Responsibilities of              --------------------------------------------------------------- Distributor. - - - -----------

     (a)    In connection with Distributor's license and distribution of the Products to End-Users, Distributor will have End-Users execute a Software License Agreement in the form attached hereto as Schedule B (the End-User License Agreement). Distributor may not negotiate the terms of the End-User License Agreement with any prospective End-User or agree to any conflicting, different or additional terms from those set forth in the End-User License Agreement without Developer's prior written consent. Developer shall have no liability to Distributor in the event any prospective End-User refuses to agree to enter into an End-User License Agreement.

     (b)   Distributor will at all times during the term hereof use all reasonable efforts to promote and increase sales of Products throughout the Territory, and will work diligently to obtain orders for Products. Developer shall, during the term hereof, adopt such policies, strategies, prices, customer license terms and conditions, and decisions which will reasonably support Distributor in promoting and increasing sales of Products throughout the Territory and shall respond to Distributor as soon as reasonably practicable with respect to the foregoing.

     (c)    Distributor will promote the sale of Products throughout the Territory to End-Users by means of personal visits, presentations, seminars, correspondence. Specific marketing and sales programs will be defined jointly by Distributor and Developer.





     (d)   Distributor hereby acknowledges that prompt, courteous and professional service of all End-Users and the fostering and maintenance of good relations with End-Users is of paramount importance to Developer, and Distributor hereby agrees to use reasonable efforts to so serve End-Users and promote such relations with End-Users. Distributor shall call upon End-Users regularly, provide assistance and information to End-Users as requested by End-Users or Developer, serve as liaison between End-Users and Developer, and comply with such policies and procedures as Developer may from time to time communicate to Distributor.

     (e)    Distributor shall take all necessary steps to ensure that it and all of its sales personnel are fully familiar with and can effectively demonstrate the Products, are familiar with the Developer's then-current price list, and applicable Developer policies and procedures.

     (f)    Distributor shall attend such annual sales and consulting meetings for, among other things, training and education as Developer shall reasonably require. Distributor

                                    2

3

shall be responsible for the cost of any travel or lodging for attendance at such meetings required by Developer.

     (g)   All payments by End-Users for Products shall be made directly to Distributor, and Distributor shall so advise Developer of the End-Users to whom sales are made.

     (h)   Distributor will not incur or create any liability on behalf of Developer or in any way pledge or purport to pledge the credit of Developer.

     (i)   Distributor will: (i) work closely with Developer to implement the agreed upon sales strategy and marketing strategy for Developer in the Territory; (ii) prepare any market survey or other marketing or sales report reasonably requested by Developer from time to time; and (iii) inform Developer promptly of any commercial, financial, technical or other information which would be of interest to Developer, including but not limited to foreseeable developments regarding End-Users' needs of which Distributor becomes aware.

     (j)   Distributor will observe all directions and instructions given by Developer in relation to Developer's commercial policy, delivery and payment terms and the distribution of Products, and, in the absence of any such directions or instructions in relation to any particular matter, will act in such manner as Distributor reasonably considers to be most beneficial to the best interests of Developer.

     (k)   Distributor will observe and take all necessary or appropriate steps to observe the standards and technical specifications applicable to Developer's business as may be communicated from time to time by Developer to Distributor.

     (1)   Developer shall be the sole source of all copies of the Products or their components distributed by Distributor under the terms of this Agreement. Furthermore, Developer's and the Product names shall appear on the initial screen in all cases. Distributor may mark all such products and materials with its own names or logos to indicate that the Distributor is a marketer of the Products, provided that any such label or lettering is no larger in size than that used for the name and logo of Developer.

     (m)   Distributor shall allocate a minimum of two (2) dedicated people to sell and support the Products full-time. Distributor shall immediately notify Developer in the event that these people are assigned additional responsibilities that prevent them from remaining dedicated to the Products full-time.

                                     3

4

     1.4  Product Changes.              ---------------

     Developer retains the right, in its sole discretion, to upgrade or modify the Products from time to time. In addition, upon ninety (90) days prior written notice to Distributor, Developer may add or delete Products from Schedule A. Upon receipt of any such notice of any upgrade or modification, or upon the expiration of the notice period set forth above for additions or deletions to Schedule A, Distributor shall cease to market and distribute earlier versions of the Products and/or Products deleted from Schedule A.

     1.5  License to Use Trademark and Trade Name.              ---------------------------------------

     Any and all trademarks and trade names which Developer uses in connection with the license granted hereunder are and shall remain the exclusive property of Developer. Nothing contained in this Agreement shall be deemed to give Distributor any right, title or interest in any trademark or trade name of Developer relating to the Products. Subject to notice in writing from Developer which modifies or cancels such authorization, during the term of this Agreement, Distributor may use at no charge the trademarks and trade names specified by Developer in writing for normal advertising and promotion of Products. Developer occasionally uses third party trademarks, trade names or screen shots in advertising; Distributor may not use such trademarks, trade





names or screen shots in writing for advertising without the prior written permission from the third party developer.

2.     PRICE, PAYMENT AND SHIPMENT.        ---------------------------

     2.1    Price.                -----

     Distributor shall adhere to the then current Developer Prices for each Product (collectively, the Prices). Developer's current Prices for each Product are set forth in Schedule C. Developer may increase or decrease the Prices for any or all Products upon written notice to Distributor. Distributor must receive, for each instance, express written permission from Developer to sell Product at any price other than such Prices.

     2.2.   Orders, Payment and Shipment.                ----------------------------

     Upon Developer's receipt of a written order from Distributor (each an Order) together with a copy of an executed End-User License Agreement and Contract Summary Form (Appendix D), Developer will ship to Distributor the designated quantities of the Products. At Distributor's expense, the Products shall be shipped by Developer to Distributor F.O.B. origin, freight pre-paid, with risk of loss to pass to Distributor upon delivery of the Products by Developer to a common carrier. Notwithstanding the above, upon notice to Distributor, Developer may ship the Software directly to Distributor's customer. The terms and conditions of this Agreement shall apply to all Orders submitted to Developer by Distributor. Orders issued by

                                   4    5

Distributor to Developer are solely for the purpose of requesting delivery dates and quantities. All Orders shall be subject to acceptance by Developer; Developer will not unreasonably delay acceptance of any order. Developer shall use reasonable efforts to deliver accepted Orders but shall not be liable for any damages to Distributor or to any third party caused by Developer's delay or error in filling, or failure to fill, any Orders for any reason. Except as otherwise provided herein, all fees and expenses payable hereunder for which Developer issues an invoice to Distributor shall be due and payable thirty (30) days from the date of the invoice. A late payment charge of the lesser of one and one-half percent (1.5%) per month or the highest interest rate allowed by applicable law shall be charged upon all unpaid amounts due hereunder for more than thirty (30) days.

     2.3 Reporting; Royalties.             --------------------

     Distributor shall submit Monthly Sales and Royalty Reports and make payments to Developer as provided herein. All royalties paid to Developer shall be based upon Developer's list prices in U.S. Dollars, except as otherwise agreed in writing by Developer.

     Software license fees associated with Software license agreements in which the sales cycle begins on or after May 1, 1994 (hereinafter New Software license agreements) for Product sites located in the Territory, shall be allocated and distributed as follows:

              Gross Software Revenue Generated     % to Distributor                  --------------------------------     ----------------                  Per Annum July 1- June 30

              US$O -- $999,999                          40%                  US$1,O00,000 +                            50%

     On July 1 each year, the gross software revenue generated figure will be reset to zero and the accumulation of software revenues will restart.

     However, the foregoing allocation of such fees associated with the New Software license agreements involving a headquarter Product or other site licenses situated outside of the Territory may be subject to reduced percentages to Distributor due to royalties owed to other Developer entities, affiliates, or distributors located outside the Territory, who may also have participated in the sale. Each such situation will be evaluated individually and a final decision on the royalty due will be based upon each party's relative contribution and will be made in Developer's sole discretion. The general guidelines for such cases are outlined in Appendix E (Bergamo Rules).

     Installation, consulting, and training fees associated with the Products are due and payable to the party performing the services.

                                    5    6

     License Renewal and Maintenance Fees will be split evenIy with 50% distributed to Developer and 50% distributed to Distributor, also subject to paragraph 4 of this section 2.3.

     Distributor will submit a monthly report to Developer which accurately identifies the Software license fees, maintenance fees, and any other fees set forth in this Agreement (repons outlined in Schedule D). This report is due at





the earliest possible time, but in no event later than ten (10) days following the end of each calendar month Payment by Distributor of the applicable royalty fees to Developer shall accompany the report; provided, however, that Developer shall have the reasonable fight to inspect Distributor's books from time to time during the term hereof and for a one (1) year period after the termination of this Agreement for purposes of verifying the royalties payable to Developer. In addition, Distributor shall report the acquisition of each new license  for the Software system to Developer and will provide either an English translation of the End-User License Agreement or a completed contract extract schedule in the form of Exhibit D (Contract Summary Form) within one (1) day of accepting the order.

     24  Inspection and Acceptance.             -------------------------

     Distributor shall inspect all Products immediately upon delivery and shall, within seven (7) calendar days, give written notice to the common cartier and Developer of any claim for damages or shortages. Distributor shall give written notice to Developer within thirty (30) calendar days of delivery in the event that any Product does not conform with the terms of this Agreement. If Distributor fails to give any such notice, the Products shall be deemed accepted for all purposes of this Agreement.

     2.5    Taxes.                -----

     In addition to the Prices and other fees payable hereunder, Distributor shall record and pay any federal, state, local or other duties, withholding and excise taxes, now or hereafter applied on the sale, transportation, import, export, licensing or use of the Products including sales tax, value added tax or similar tax. Any taxes imposed by federal, state or any local government or any amount in lieu thereof, including interest and penalties thereon, paid or payable at any time by Developer in connection with Developer's license to Distributor, exclusive of taxes based on Developer's net income, shall be borne by Distributor.

     Distributor shall co-operate with and assist Developer, as reasonably necessary, to obtain United States tax credits for any duties or taxes described in this Section 2.5 which may be credited to and/or recovered by Developer and applied by Developer to reduce its United States tax liability. In the event Developer obtains any such tax credits, Developer shall notify Distributor of the amount thereof and Distributor shall be entitled to apply such amount against future amounts payable by Distributor to Developer hereunder.

                                    6

7

3.  MAINTENANCE AND SUPPORT.     -----------------------

     3.1   Distributor Support               -------------------

     Distributor shall remain solely responsible for all installation, maintenance, consulting and support services to the End-Users with regard to the Products. Developer agrees to deliver to Distributor together with the first Order delivered to Distributor a copy of the Product to be used solely by Distributor's personnel providing installation, maintenance, consulting or support services to End-Users and shall only be used at Distributor's site. Distributor's failure to maintain the confidentiality of the Products pursuant to the terms of this Agreement shall be deemed a material breach of this Agreement. As mutually agreeable, Developer, Developer's affiliates, or Distributor may each provide local support to the sites of multi-location clients, each on behalf of the other where the provisions of such support will enhance the quality of support provided to the client. Such services will be provided at the local billing rate or such alternative billing rate as shall be agreed between the parties. The party providing the support shall receive all revenues arising therefrom unless otherwise agreed. Furthermore, it is understood that travel expenses, if any, are to be borne by the client utilizing the support services or by the Distributor unless otherwise agreed. For End-Users that have a World Wide Retainer in place, Distributor will provide local support in the Territory as defined in the World Wide Retainer (Schedule F).

     3.2    Audit Rights.                ------------

     Distributor shall maintain accurate books and records of all End-User License Agreements granted for the Products (which will include at a minimum the location, type and number of products and sites, renewal and payment terms and any special conditions or terms), the End-Users receiving maintenance, and consulting and support services, payable under this Agreement. Upon reasonable notice to Distributor, Distributor shall make such books and records available to Developer, at Distributor's place of business during normal business hours, to audit the payments being made by Distributor hereunder.

     3.3  End-User Training and Developer Consulting Services              ---------------------------------------------------

     Distributor shall be solely responsible for the training of End-Users. Developer may be available at its then current standard rates to provide training, special enhancements, customization and other special work or services to either Distributor or End-Users.





                                    7

8

4.     CONFIDENTIALITY AND PROPRIETARY RIGHTS.        --------------------------------------

     4.1    Confidentiality.                ---------------

     Distributor acknowledges that in the course of dealings between the parties, Distributor may acquire information about Developer, its business activities and operations, its technical information and trade secrets, including but not limited to the Products, all of which are highly confidential and proprietary to Developer (the Confidential Information). Confidential Information shall not include information generally available to or known by the public, or information independently developed outside the scope of this Agreement. Distributor shall hold all such Confidential Information in strict confidence and shall not reveal or use the same except pursuant to a court order or upon written request of Developer. The Confidential Information shall be safeguarded with at least as great a degree of care as Distributor uses to safeguard its own most confidential materials or data relating to its own business, but in no event less than a reasonable degree of care.

     4.2    Proprietary Rights.                ------------------

     Distributor acknowledges and agrees that the Products, and all copies thereof, constitute valuable trade secrets of Developer and/or proprietary and confidential information of Developer and title thereto remains in Developer. Ownership of all applicable copyrights, trade secrets, patents and other intellectual property rights in the Products are and shall remain vested in Developer. All other aspects of the Products, including without limitation, algorithms, models, programs, methods of processing, design and structure of individual programs and their interaction and programming techniques employed therein shall remain the sole and exclusive property of Developer and shall not be sold, revealed, disclosed or otherwise communicated, directly or indirectly, by Distributor to any person, company or entity whatsoever other than as expressly set forth herein. The copyright notice and restricted rights legends contained in the Products shall appear on all tapes, diskettes and other tangible media distributed by Distributor.

     4.3    Specific Remedies.                -----------------

     If Distributor commits a breach of any of the provisions of Sections 4.1 or 4.2 above, Developer shall have, in addition to all other fights in law and equity, (a) the right to have such provisions specifically enforced by any court having equity jurisdiction, it being acknowledged and agreed that any such breach will cause irreparable injury to Developer and that money damages will not provide an adequate remedy, and (b) the right to require Distributor to account for and pay to Developer all compensation, profits, monies or other tangible benefits (collectively Benefits) derived or received as the result of any transactions constituting a breach of any of the provisions of this Article 4, and Distributor hereby agrees to account for and pay such Benefits.

                                    8

9

     4.4    Covenant Not to Compete.                -----------------------

     During the term of this Agreement and for a period of two (2) years after the termination hereof for any reason, Distributor will not market, or attempt to market, a computer program which competes in any way with the Products in the areas of consolidation, financial information, financial transaction processing, reporting, data collection, or modeling, including but not limited to the use of personal computers, nor which competes with any modification, alteration or enhancement to the Products which is developed during the term of this Agreement.

5.  LIMITED WARRANTY.     ----------------

     5.1 Limited Warranty.             ----------------

     For ninety (90) days after delivery of a Product to Distributor, Developer warrants that media upon which the Products are delivered shall be of good quality and workmanship. Upon written notice from Distributor of defective media for a Product, Developer shall use reasonable efforts to promptly provide replacement media.

     5.2 Disclaimer of Warranties.             ------------------------

     EXCEPT FOR THE LIMITED WARRANTY SET FORTH IN SECTION 5.1, THE PRODUCTS ARE PROVIDED AS IS. DEVELOPER SPECIFICALLY DISCLAIMS ALL WARRANTIES EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO, IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE WITH RESPECT'TO THE PRODUCTS OR DEFECTS IN THE TAPE, DISKETTE OR OTHER TANGIBLE MEDIA AND DOCUMENTATION, OPERATION OF THE PRODUCTS, AND ANY PARTICULAR APPLICATION OR USE OF THE PRODUCTS.

6.       LIMITATION OF LIABILITY.          -----------------------





     IN NO EVENT SHALL DEVELOPER BE LIABLE FOR ANY LOSS OF PROFIT OR ANY OTHER COMMERCIAL DAMAGE, INCLUDING BUT NOT LIMITED TO SPECIAL, INCIDENTAL, CONSEQUENTIAL OR OTHER INDIRECT DAMAGES UNDER ANY CAUSE OF ACTION ARISING OUT OF OR RELATING TO THIS AGREEMENT, INCLUDING, WITHOUT LIMITATION, CLAIMS ARISING FROM MALFUNCTION OR DEFECTS IN THE PRODUCTS. DEVELOPER'S MAXIMUM LIABILITY HEREUNDER IS EXPRESSLY LIMITED TO THE LESSER OF: THE AMOUNT PAID UNDER THIS AGREEMENT BY DISTRIBUTOR TO DEVELOPER WITHIN THE SIX (6) MONTH PERIOD IMMEDIATELY PRECEDING THE CAUSE GIVING RISE TO THE CLAIM; OR FIVE HUNDRED THOUSAND DOLLARS ($5OO,000).

                                    9

10

7.  DISTRIBUTOR OBLIGATIONS.     -----------------------

     7.1    Marketing Efforts.                -----------------

     Distributor agrees to use its best efforts to promote the sale of the Products in the Territory. Distributor agrees to permit Developer to review all of Distributor's promotion and advertising material for the Products prior to use. Distributor shall not use and shall withdraw and retract any promotion or advertising that Developer finds unsuitable, or is in breach of the terms of this Agreement.

     7.2   Prohibited Practices.                --------------------               Distributor may not make any contracts or commitments on behalf of Developer nor make any warranties or other representations regarding the Products other than those authorized herein or by Developer in a separate writing.

     7.3   Export Notice.               -------------

     Distributor agrees to provide Developer with reasonable advance notice of each country- to which it intends to export the Products. Prior to exporting to a foreign country for the first time, Distributor shall provide Developer with a reasonable opportunity to file such proprietary rights notices, applications, and other documents as Developer determines to be reasonably necessary to protect in such country the proprietary rights associated with the Products. Distributor agrees at Developer's expense to cooperate with Developer in the protection of such proprietary rights in each country to which it exports the Products.

     7.4  Compliance with Laws.              --------------------              Distributor agrees to comply with all applicable laws and  regulations, both foreign and domestic, in its performance under this Agreement, including, but not limited to, domestic and foreign export/import laws and regulations.

8.  TERMS AND TERMINATION.     ---------------------

     8.1  Term.              ----

     This Agreement shall have an initial term of one (1) year from the date first above written (the Initial Term), and shall thereafter automatically renew for successive two (2) year periods (each a Renewal Term), unless earlier terminated in accordance with the terms of this Agreement. Developer may cancel this Agreement if the total gross annual software revenue does not meet DeVeloper's revenue forecast for the Distributor, such cancellation to be eftected by written notice delivered to Distributor not later than 30 days after any Developer's Fiscal Year end (June 30). Either party may cancel this Agreement effective on the last day of the Initial Term, or

                                      10    11

any Renewal Term, by serving written notice of such termination on the other party at least ninety (90) days prior to the end of the Initial Term or any Renewal Term as the case may be.

     8.2   Developer Termination.               ---------------------

     This Agreement may be terminated immediately by Developer under any of the following conditions:

     (a)   if one of the parties shall be declared insolvent or bankrupt;

     (b)   if a petition is filed in any court to declare one of the parties bankrupt or for a reorganization under the Bankruptcy Code or any similar statute and such petition is not dismissed in ninety (90) days or if a Trustee in Bankruptcy or a Receiver or similar entity is appointed for one of the parties;

     (c)   if Distributor does not pay Developer within thirty (30) days from the date that any payments are due hereunder;





     (d)   if Distributor breaches the provisions of Sections 4.1 or 4.2 of this Agreement; or

     (e)   if Distributor otherwise materially breaches the terms of this Agreement, and such breach is not cured within thirty (30) days after written notice of such breach is given by Developer.

     8.3   Duties Upon Termination.               -----------------------

     (a)    Provided termination is not a result of a material breach of Sections 4.1 or 4.2, the parties agree to continue their cooperation in order to effect an orderly termination of their relationship. Distributor may continue running the Products solely for purposes of providing maintenance to End-Users granted licenses pursuant to an End-User License Agreement prior to termination. Upon termination, Distributor shall have no fight to order or receive any additional copies of the Products and all of Distributor's rights and licenses granted hereunder shall immediately cease. Within thirty (30) days of termination, Distributor shall return all copies of any promotional materials, marketing literature, written information and reports pertaining to the Products that have been supplied by Developer.

     (b)    Upon termination of this Agreement for any reason, Distributor shall forthwith return all Products, documentation and materials relating thereto to Developer. Termination of this Agreement shall not relieve Distributor of any financial obligations to Developer which remain unsettled at the date of termination, nor of the terms relating to proprietary rights, trade secrets, or non compete restrictions; provided, further, that if this Agreement is terminated for any reason, Developer shall have the option, but not the obligation to

                                    11    12

assume at no cost to Developer, any or all of Distributor's third party agreements (including End-User Agreements) relating to the Products and to receive any and all fees therefrom.

     8.4  Survival              --------

     The provisions of Sections 4, 5 and 9 shall survive the termination of this Agreement.

9.   INDEMNIFICATION.      ---------------

     9.1    Copyright Indemnification.                -------------------------

     Developer shall indemnify, defend and hold Distributor harmless from any claims, demands, liabilities or expenses, including reasonable attorneys' fees, directly resulting from any infringement or violation of any copyright with respect to the Product(s), as so awarded by a final judgment against Distributor by a court of competent jurisdiction that the Product(s) infringe any third party's copyright, Developer shall, in its sole discretion:

     (a)   procure for Distributor the right to continue to use, distribute and sell the Product(s) at no additional expense to Distributor;

     (b)   provide Distributor with a non-infringing version of the Product(s) with substantially similar functionality; or

     (c)   notify Distributor that the Product(s) are being withdrawn from the market and Distributor agrees to immediately cease its distribution of such Product(s). If all Products are withdrawn from the market, this Agreement will immediately terminate.

     9.2   Cooperation by Distributor.               --------------------------

     Notwithstanding Section 9.1 of this Agreement, Developer is under no obligation to indemnify and hold Distributor harmless unless:

     (a)    Developer shall have been promptly notified of the suit, action, proceeding or claim by Distributor and furnished by Distributor with a copy of each communication, notice or other action relating to said suit, action, proceeding or claim;

     (b)    Developer shall have the right to assume sole authority to conduct the trial or settlement of such suit, action, proceeding or claim or any negotiations related thereto at Developer's expense; and

     (c)    Distributor shall provide reasonable information and assistance requested by Developer in connection with such claim or suit.

                                     12

13

     9.3    Distributor Indemnification.                ---------------------------

     Distributor shall indemnify, defend and hold Developer harmless from





any claims, demands, liability or expenses, including reasonable attorneys' fees, incurred by Developer as a result of any claim or proceeding against Developer arising out of or based upon (i) the combination, operation or use of the Products with any hardware, products, programs or data not supplied or approved in writing by Developer, if such infringement would have been avoided but for such combination, operation or use (ii) modification of the Products by Distributor or End- Users(iii) any breach of this Agreement by the Distributor or (iv) any breach by the Distributor of any End User or other agreement to which Developer or Distributor is a party.

10.   GENERAL.       -------

     10.1  Force Majeure.               -------------                        Neither party shall be liable or deemed to be in default for any delay or failure in performance (other than the payment of money) under this Agreement or interruption of service resulting directly or indirectly from acts of God, or any causes beyond the reasonable control of such party.

     10.2  Jurisdiction and Venue.               ----------------------

     This Agreement shall be governed by and construed in accordance with the laws of the State of Connecticut, U.S.A. without regard to its conflict of taws provision. Jurisdiction for litigation of any dispute, controversy or claim arising out of or in connection with this Agreement, or the breach thereof shall be only in the Federal or the State court with competent jurisdiction located in Stamford, Connecticut.

     10.3  Entire Agreement.               ----------------

     This Agreement, including the Schedules attached hereto, constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all previous proposals, both oral and written, negotiations, representations, commitments, writings and all other communications between the parties. This Agreement may not be modified except by a writing signed by a duly authorized representative of each of the parties.

                                     13

14

     10.4   Independent Contractors.                -----------------------

     It is expressly agreed that Developer and Distributor are acting hereunder as independent contractors and under no circumstances shall any of the employees of one party be deemed the employees of the other for any purpose. This Agreement shall not be construed as authority for either party to act for the other party in any agency or other capacity, or to make commitments of any kind for the account of or on behalf of the other except to the extent and for the purposes provided for herein.

     10.5   Assignment.                ----------

     This Agreement is not assignable by either party hereto without the prior written consent of the other, except that this Agreement shall be assignable by Developer to an affiliated entity or upon the sale of the fight to license and sublicense the Products to the purchaser of said right. This Agreement shall be binding upon and inure to the benefit of the parties and their respective successors and permitted assigns.

     10.6   Severability and Waiver.                -----------------------

     If any provision of this Agreement is determined by a court of competent jurisdiction to be invalid or unenforceable, such determination shall not affect the validity or enforceability of any other part or provision of this Agreement. No waiver by any party of any breach of any provisions hereof shall constitute a waiver unless made in writing signed by the party.

     IN WITNESS WHEREOF, the parties hereto have executed this Agreement by a duly authorized representative as of the date set forth above.

     DISTRIBUTOR:                            DEVELOPER:         -----------                             ---------         DELTEQ SYSTEMS PTE LTD                  IMRS OPERATIONS INC. d/b/a                                                 IMRS INC.

     By:   /s/ S.C. CHEN                     By: /s/ DAVID M. SAMPLE               --------------------                  -----------------------

     Name: S.C. Chen                         Name: David M. Sample                                                       ---------------------

     Title: Managing Director                Title: Senior Vice President

                                       14 
Question: Highlight the parts (if any) of this contract related to Warranty Duration that should be reviewed by a lawyer. Details: What is the duration of any  warranty against defects or errors in technology, products, or services  provided under the contract?
23920

EXHIBIT I TO SCHEDULE A (COMPLIANCE WITH UNITED STATES SECURITIES LAWS) AGENTS' CERTIFICATE In connection with the offer and sale in the United States of common shares (the Securities) of Tribute Pharmaceuticals Inc. (the Corporation) to Accredited Investors pursuant to a Subscription Agreement dated as of May 22, 2015, and pursuant to an agency agreement (the Agency Agreement) dated as of May 22, 2015 between the Corporation and the agents named therein, [ ] (the Agent) and [ ] (the U.S. Affiliate), the U.S. registered broker-dealer affiliate of the Agent, hereby certify as follows: (i) on the date hereof and on the date of each offer of Securities by us in the United States and each subsequent sale to such offerees by the Corporation, the U.S. Affiliate is and was: (A) a duly registered as a broker-dealer under the U.S. Exchange Act and duly registered as a broker-dealer under the laws of each state where it made offers of Securities (unless exempt from such registration requirements); and (B) a member of and in good standing with the Financial Industry Regulatory Authority, Inc.; (ii) all offers of Securities by us in the United States have been effected by the U.S. Affiliate in accordance with all applicable U.S. federal and state broker-dealer requirements; (iii) immediately prior to offering the Securities to persons in the United States, we had reasonable grounds to believe and did believe that each such person was an Accredited Investor, based upon a pre-existing relationship, and, on the date hereof, we continue to believe that each such offeree purchasing Securities from the Corporation is an Accredited Investor; (iv) no form of Directed Selling Efforts, General Solicitation or General Advertising was used by us in connection with the offer of the Securities by us in the United States, and we have not acted in any manner involving public offering within the meaning of Section 4(a) (2) of the U.S. Securities Act in connection with the offer of the Securities by us in the United States; (v) in connection with arranging each sale by the Corporation of Securities to U.S. Subscribers solicited by us, we caused each such U.S. Subscriber to duly complete and execute a Subscription Agreement to be used for U.S Subscribers; (vi) the Agent represents and warrants that with respect to Offered Shares to be sold in reliance on Rule 506(b) of Regulation D, none of it, the U.S. Affiliate, any of its or the U.S. Affiliate's directors, executive officers, general partners, managing members or other officers participating in the Offering, or any other person associated with the Agent who will receive, directly or indirectly, remuneration for solicitation of Subscribers of Offered Shares pursuant to Rule 506(b) of Regulation D (each, a Dealer Covered Person and, together, Dealer Covered Persons), is subject to any Disqualification Event except for a Disqualification Event (i) covered by Rule 506(d)(2)(i) of Regulation D and (ii) a description of which has been furnished in writing to the Corporation prior to the date hereof;





(vii) the Agent represents that it is not aware of any person (other than any Dealer Covered Person) that has been or will be paid (directly or indirectly) remuneration for solicitation of Subscribers in connection with the sale of any Offered Shares pursuant to Rule 506(b) of Regulation D; and (viii) the offering of the Securities in the United States has been conducted by us in accordance with the terms of the Agency Agreement, including Schedule A attached hereto. [REMAINDER OF PAGE INTENTIONALLY LEFT BLANK]





Terms used in this certificate have the meanings given to them in the Agency Agreement, including Schedule A attached hereto, unless otherwise defined herein. Dated this day of , 2015. [INSERT NAME OF AGENT] [INSERT NAME OF U.S. AFFILIATE] By: By: Name: Name: Title: Title: 
Question: Highlight the parts (if any) of this contract related to Agreement Date that should be reviewed by a lawyer. Details: The date of the contract

3790