davidaulloa/AmericanStories huggingface dataset:
Arizona republican., 1919-08-07
Legal Advertising

tial sets of plans and specifications for estimate, on request or by appointment, and the return of such plans and speci- fications must be guaranteed by de- posit Of ten dollars which deposit will be refunded on return of the plans and specifications in good order
 Every such proposal must be accom- panied by certified check for five per cent of the amount of the bid included in the proposal, as a guarantee of the intent of the contractor to enter into contract with School Distict Number 14 of Maricoja County Arizona, to well and truly perform all the matters in- cluded in the said proposal and in ac- cordance with the plans and specifica- tions, or as liquidated damages in the event of failure or refusal on the part of the contractor to enter into the con- tract as above named
 Said certified checks will be returned to the contractors whose proposals are not accepted, and to the successful con- tractor upon the execution of a satis- factory bond and contract as herein after provided.
 The School District Number 14 re- serves the right to reject any or all proposals, or to withhold the award if for any reason it may so determine. All bids must be delivered to w. S. Wilson, Clerk of the Board of Trustees of the said School District whose post office address is Route 2, Phoenix, Arizona, at or before S:30 P. M. Mon- day, August II 1919.
 All bids will be opened by the Board of Trustees of the said School District at the East School Building in School Each bidder is required to state in his proposal the time In which he will guarantee to complete the construction of the work proposed. All bids should be sealed and properly marked.
 DONE by order of the Board of Trustees of School District Number IA of Maricopa County. Arizona, this 25th day of July A. D.. 1919.
 TOM HURST.
 Chairman.
 W. s. WILSON,
 Clerk
 MRS. c. ". McRAE,
 Member. Trustees of School District No. IA oi Maricopa County, Arizona. c
Arizona republican., 1919-08-07
WILL ADVANCE IN 1919 copper ABOVE WAR PRICES
 Boston Copper News Vow wins. i" Sixth

Mailed on request FREE. To keep posted on "Coppers," "SiIvers" and all metal shares, our complete statistical service is at your command. Send to day to Boston Copper News, Dept. 64, Boston, Mass.
Arizona republican., 1919-08-07
NOTICE OF HEARING PETITION
 No. 3f65

In the Superior Court of Maricopa county, state of Arizona.
 In the matter of the estate of Walter Talbot, deceased.
 Notice is hereby given that Henrietta H. Talbot has filed in this court a cer- tain document purportihg to be the last will and testament of Walter Tal- bot, deceased, together with her peti- ton praying that said docdment be ad- mitted to probate in this court as the last will and testament of said Walter Talbot, who, said petitioner alleges, is deceased, and that letters testamentary issue thereon to said petitioner, and that same will be heard Monday the 11th day of August, A. D., 1919, at 1:30 o'clock in the afternoon of said day, at the court room of said court, in the court house. in the city of Phoenix, county of Maricopa, state of Arizona, and all persons interested in said estate are -.otified then and there to appear and show cause, if any they have. why the prayer of said petitioner should not be granted.
 CLAUDE s. BRENNAN,
 Clerk. By W. H. LINVILLE,
 Deputy Clerk. Court SeaD
 Dated July 2Sth, 1919.
Arizona republican., 1919-08-07
NOTICE TO CONTRACTORS

On or before August 20, 1919. the Board of Regents of the University of Arizona will received sealed proposals for a general contract required in and for a forernans residence at the Uni versity of Arizona Experimental Farm at Mesa, Arizona Plans and specified tions may be obtained from the fore man, c. J. Wood, Mesa, Arizona, or from President R. B. von KleinSmid. Tucson, Arizona. together with full in- formation as to the proposed work. and are on file for inspection at the ex perimental Farm near Mesa. Arizona and at the office of the president of the university, Tucson, Arizona. Con tractors desiring to submit proposals for estimates on request or by appoint ment and the return of such plans and specifications must be guaranteed by a deposit of s15 which deposit will be refunded on the return of the plans and specifications in good order.
 Every such proposal must be ac- companied by certified check for five per cent of the amount of the bid in- cluded in the proposal as a guarantee of the intent of the contractor to enter into a contract with the board of reg . ents of the University of Arizona to well and truly perform all the matters included in the said proposal; and in accordance with the plans and specifi- cations, or as liquidated damages in the event of failure or refusal on the part of the contractor to enter into contract as above named.
 Said certified check will be returned to the contractors whose proposals are not accepted and to the successful con tractor upon the execution of satis factory bond and contract as herein after provided.
 The Board of Regents of the Univer sity of Arizona reserve the right to reject any or all proposals or to with hold the award if for any reason il may so determine.
Arizona republican., 1919-08-07
By W. H. LINvILLE,
 Deputy Clerk. Court SeaD Dated July 2Sth, 1919.
NOTICE TO CONTRACTORS


 The Board of Trustees of School District No. IA of Maricopa County, State of Arizona, will receive sealed proposals for a general contract in- cluding rything required in and for one brick ole story building for school purposes. one frame one story building District Number IA, Maricopa County. Arizona, at s:30 o'clock in the evening of the 11th day of August. 1919. and thereafter considered.
 for school purposes and an addition to the present East School Building of School District Number IA. the pro- posed location of the said school build ings and addition being on the school grounds now owned by School District Number IA of Maricopa County, State of Arizona.
 Plans and specifications prepared by Henry O. Jaasted, architect, whose ad- dress is Tucson, Arizona. may be ob- tained from the County Superintendent of Schools of Maricopa County, Ari- zona. at Phoenix Arizona, together with full information as to the proposed work. after July 30. 1919. and will be on file for inspection thereafter at the office of the said County Superinten- dent of Schools in the Court House Of Maricopa County at Phoenix, Arizona.
 Contractors desiring to submit pro- posals may obtain copies of full or par
Arizona republican., 1919-08-07

tung breaking out here and there, like blotch from the operation of a dull safety razor blade on the face of this, that or the other solar system; but Shantungs are trivial details; certain number of Shantungs in a Cosmos are, we must suppose, unavoidable; every little planet has a Shantung of it's own. Anyhow, what's a Shantung between friends?
 May we not suggest that if some thing of this sort is not done the Heart of the Universe may Break?
Arizona republican., 1919-08-07
Legal Advertising
NOTICE OF SCHOOL BOND
 ELECTION

ELEC HUN
 Pursuant to a resolution of the board of trustees of school district No. 6S of Maricopa county, state of Arizona, duly passed and adopted on the 18th day Of July, 1919, calling the election herein after mentioned notice is hereby given that an election will be held in the school building of the said school dis trict on Friday, the sth day of August, A. D., 1919, from the hour of 10 o'clock in the forenoon to the hour of o'clock in the afternoon of said day, during which time the polls will be open; that J. D. Cage, Mary Jack and Emma Sine are the judges named and ap- pointed to conduct the said election at said time and place: that the purpose Of the said election is to submit to the taxpayers who are otherwise qualified electors of the said school district the question whether or not the bonds of said school district No. 6S shall be is- sued and sold in the aggregate amount of eighteen thousand dollars, N1S,- 000.00), in tho denomination of five hundred dollars (s50000) each, bearing interest at the rate of six per cent per annum, payable semi annually, and to run for twenty years after the date of the issuance thereof; the proceeds of said bonds to be used and expended in the erection of two additional school buildings upon the school grounds now owned by the said district; supplying the said buildings with necessary fur niture and apparatus and improving the school grounds.
 Dated this 18th day of July, A. D.. s919.
 Board of Trustees of School District Number 6S of Maricopa County, State of Arizona.
 By HUGH NJ. JONES,
 Chairman.
 PHIL c. ENSIGN,
 Clerk.
 c. K. GREEN,
Arizona republican., 1919-08-07
NOTICE TO CoNTRACTORs

Trustees of School District No. IA o
 Maricopa County, Arizeua.
Arizona republican., 1919-08-07

The Board of Trustees of School District No. 22 of Maricopa county, state of Arizona, will receive proposals for the erection of a school building. Plans and specifications may be found at Room (6) Creighton Building in the office of J. NJ. Creighton (archi- tect.) All bids must be in before : D. m. Tuesday, August 18th. 1919. The bids will be opened in the presence of bidders by the Board of Trustees of the aforesaid district
 J. H. MITCHELL,
 Clerk.
Arizona republican., 1919-08-07

pings and food issues. gains ran from to 15 points. Sales, 1,350,000 shares.
 Bonds, including Liberty issues, were irregular the foreign group showing no definite trend Total sales, par value, $s.750,000.
 Old United States bonds unchanged OF call
Arizona republican., 1919-08-07

Because of labor troubles in the val ley and delta districts of the San Joa- quin river in California, which sup plies Phoenix with the greater part of the potatoes consumed, there is likely to be a great shortage here. There is also a car shortage, and prices may take a further rise in all lines of pro- duce as a result of this.
Arizona republican., 1919-08-07
LIVESTOCK
Chicago


 CHICAGO, Aug. 6.-Hogs- Receipts, 1000; market steady; top, s22.25; heavy weight, s20.10Q22.10; medium weight, s2025@2225; light weight, s20.00@22.15; heavy packing sows, s19.00@ 20.00; pigs, s17.50@19.00. Cattle - Receipts, 1000; market strong; medium and heavy weight, choice prime, $12.7561S90; medium and good, s124o@1725; butcher cattle, heifers, $7.0o@14.65; cows, $6.75 613.S5; canners and cutters, $5.75@6.75; calves. s1725@1S.25; western range steers, s9.00@16.25; cows and heifers s7.25@1275.
 Sheep-Receipts, 10000; market un- settled; lambs, s1S.40%16S5; ewes, $7.00@900; culls and common, $275@ $50. DENVER, Aug. -Cattle-Receipts 5G0; market stronger; beef steers, $11.50G 14.00; cows and heifers, s7.75@ 300; calves. s12.00@14.00.
 Hogs-Receipts, 400; market 25c lower; top, s21.60; bulk, $2100@21S5. Sheep Receipts, 5000; market steady to strong. Lambs, s14.75@ 1850; ewes. sS.OO@S.50 feeder lambs, $1200@13.25.
 MERCANTILE PAPER
 NEW YORK, Aug 6.-Mercantile paper unchanged; sterling, demand. s4.31; cables. s4.32; francs, demand, 7.26c; cables, 7.60c. Time loans strong, unchanged; call moneq easy high per cent, low 312, ruling rate 6, closing bid 3lA, offered at 4, last loan 31a.
 NEW YORK, Aug. Cooper and iron unchanged. Lead easy, spot 5.45c, September 5.60c Spelter weak; East St. Louis delivery. spot offered at 7.50c; September, 7.60c.
 GRAIN
 CHICAGO, Aug. 6.-Close: Corn-Septemher. s1.S114; Deeem- Der, s151
 Oats-Septemher 721ec; December 75isc.
 Pork-September s46.40.
 Lard-September s31.40; October $3125.
 Ribs-September, s263O
 COTTON NEW YORK, Aug 6-Cotton closed very steady at net advance of 5S tc 80 points Spot steady, 32.75c.
Arizona republican., 1919-08-07

COTTON NEW YORK, Aug 6.-Cotton closed very steady at a net advance of 5S to so points. Spot steady, 32.75c.
Arizona republican., 1919-08-07
Turkish Baths

VAPOR, sulphur and shower baths, spinal, body massage, vibration and physiological exercises, mems and women's departments; expert attend ants. Our special hot weather treat ments will please you. Phone 491s for appointment. 137 North Central ave .nue. If
 ELECTRIC Cabinet-Sweat, Vapor and shower baths. Nurse in attend- ance for ladies. DeMarvel Institute. 124 N. First Ave. If
Omaha daily bee., 1919-06-15
Soldier $ Plea Saves
His Aged Mother From
Jail for Being Drunk

Boston, June 1.-THE appeal
made by Mary Gallagher's war hero
son saved her from jail sentence
when she appeared in the superior
criminal court charged with drunk
cnncss.
As the defendant, a gray haired
mother of three sons in the service.
listened to the long record produced
by the probation officer, she glanced
at her soldier son, who was present
in the court.
Assistant District Attorney Shee-
han, too, saw the mute understand
ing between the pair, and called the
boy to the stand.
when returned from France re-
recently I went home and found my
mother was not there" he said. ~
4 inquired and learned she was in jail.
was gassed and wounded in
France. | served there 18 months.
Ixhave hired tenement and would
ike my other home"
We'll, for the sake of your soldier
boy and not for your sake / will
give you chance,p said Judge Cal
lahan. IF you have any heart you
will appreciate what he did for you
and stop drinking. ! will file the
complaints"
Omaha daily bee., 1919-06-15
Samuel Carr Wins His
Suit Against City After
10 Years Of Litigation

A judgment for $12,427.13 in the
case Of Samuel Carr against the City
Of Omaha was handed down by Dis
trict Judge Redick yesterday after
more than 10 years of litigation. It
was next to the Oldest case on the dis
trict court docket.
In April, 1907, the city council
passed resolution taking so acres
of land at the southeast edge of Car
ter lake for park purposes. APP
praisers set the value of the 90 acres
II $lo1.30. The owners filed a petit
tion in district court for $4,000 on
August 7, 1908.
Since then the case has been
fought. 1t was taken to the supreme
court twice and finally the city COM
llissioners agreed to the judgment
approved now by Judge Redick.
Omaha daily bee., 1919-06-15
COMPOSER TOLD
LOVE ANDHATE TO
WIFE IN HIS SONGS
tBy UniversaI service.)

New York. June 14.-It's a long
bark from being the inspiration for
the writing by her husband of the
song, "Onc in a Million Like You,"
and after two years of married life
the, inspiration for the song, "Slt
Down, You're Rocking the Boat"
But that is what Mrs. Helen Clarke
alleged in testifying in the supreme
court in her suit for 4 divorce
against her song writer husband,
Grant Clarke. Her sister, Miss
1nez Patteu, testifying to having dis
covered ia Clarke's apartments here
during raid a striking blonde,
whom she described as the song
writer's new inspiration"
"Mr. Clarke and I were married
As minutes after we met, four years
ago, in Kokomo, Ind.," said Mrs:
Clarke while testifying. "He told
me I was his inspiration, the wife
he had been dreaming about for
many years.
aPefore he married me he wrote
Omaha daily bee., 1919-06-15
WITNESS STATES
JUDGE ACCEPTED
100000 BRIBE
Declares HenshaW Promised
ito See What He Could Do"
About Reversing Ruling in
Fair viii Case.

San Francisco, June l4.-William
J. Dingee, under oath in deposi-
ton taken here today, asserted that
100000 had been paid Frederick w.
Henshaw, then justice of the state
supreme court, after Henshaw told
him, Dingee said, he would see
what he could do in regard to re-
versing a decision OF the supreme
court so as to effect a breaking Of
the trust clause il. the $22,000,900
will of James G. Fair
The final decision of the supreme
court in the rase was March ~.
1902.
The deposition was taken by at
torneys of heirs of Fair, who are
seeking to reopen the will contest.
A superior court ruling on mo
ton by defendants in the case to
annul the deposition proceedings
yesterday, permitted taking Of the
deposition June "a, but attorneys
for the heirs announced they would
proceed today.
Took 100000 in Checks.
Dingee, under examination, said
that the late George A. Knight. ore
time attorney in the Fair will con-
test, interested him in connection
with Henshaw, then justice. He
said that he took 100000 in checks,
signed by S. G. Murphy, president
of the First National bank, for de-
livery to Henshaw, and entered the
checks in account of 81. Brown" in
his brokerage offices. Dingee said
he opened the 81. Brown" account at
the request OF Henshaw, for Hen
shaw later rendered $4,000 through
other agencies and other means to
Henshaw.
The deposition was taken by at
torneys representing Wesley Croth
ers and others as claimants to the
Fair estate, who avetfiled with the
superior court here an action to re-
open the will case on charges that
the final disposition of the case in.
VOWED irregularities, including tie
alleged receipt Of $4,000 by one
of the Justices, Henshaw, to in
ffuence decision.
Omaha daily bee., 1919-06-15
RECLAIM LAND
IN NENCLANDFOR
USE Of HEROES
Coast Land Will Be Given Dis
abled Soldiers to Make
Them Independent Of
Charity.
By WILLIAM L. MALLABAR,
International News Service Staff
Correspondent.

London. June 14.-How to make
discharged and disabled-or partial
ly so--soldiers, and sailors inde-
pendent of public or private charity
IS one of the questions that is at
present occupying the attention of
many people in England. L.
Thomas H. Mawson, the we'll
known architect and town planner,
who was perhaps the first man 10
see the vital necessity of arrang-
ing for the future of the disabled
soldier and whose book on this
subject attracted general and Sc
rious attention, has sketched out a
plan for giving the discharged men
! permanent and comfortable home.
with certainty of material profits.
AT the same time. while the dis
abled or partially disabled men are
10 benefit by this, the project is
also open to men who, having done
their "bit." are looking for settled
home life.
The proposition is to place these
men on reclaimed land around the
English coast. There are many
places where the tide flows in twice
. day over good rich land. This
land is to be reclaimed and given
to the discharged soldiers for culti-
/ walton. The British board. of agri-
culture has already arranged to sur,
vey these sections and build sea
walls to protect the land
One place has already been start
ed at Mcathrop, a little village near
Liverpool. A corporate body known
as the Industrial Settlements. in
corporated, has been formed and .his
society has arranged for the in
struction of the settlers in the art
ct afforestration and plant grow
ing, expert instructors having been
engaged for this purpose. All
products OF the land will be sold
through the society and the settle
ments themselves will be run on
proiit-sharing basis, the organiza-'
tion taking nothing from the pro-
cccds and the soldiers dividing the
money according to pre-arrange-
ment.
The reason for asking for land
near large cities is that it has been
discovered that soldiers who have
been used to mingling with their
fellows in camps and fields on the
various battlefronts are not willing
to 60 to places where they may
be shut off from companionship, ex-
cept at some expenses of time and
money to reach more crowded dis
tricts.
Omaha daily bee., 1919-06-15
Boy Scout Committee Urges
Mailing of Subscriptions

The Boy Scout drive for $4,000
Is drawing to close and the COM
mittee having the campaign in
charge finds that many who should
have contributed to this worthy
cause have neglected to subscribe.
1t is impossible for the committee
to visit each individual and The
Zee has been asked to take care Of
mail subscriptions.
Mail your check for 81 or more
either care of The Bee or to the
Committee direct. Ali subscriptions
sent to The Bee will be PROMPTLY
remitted to the committee. Sub
scriptions will be taken today.
Omaha daily bee., 1919-06-15

One in Million Like YOU and for
two years / was the you Then
we had differences and he wrote
Sit Down, You're Rocking the
Boat
About the time he was first seen
by my friends with blonde he
wrote I Love the Ladies and
There's Little Bit Of Bad in Every
Good Little Girl About that time
/ sued him for divorce and he wrote,
I Hate to Lose You,' but / didn't
know whether he meant me or the
blonde"
Decision was reserved by Supreme
Court Justice Giegerich.
Omaha daily bee., 1919-06-15

Joseph Stowers Company 42d Div
Sergeant fell with boche the Champagne front
coming Germans advancing msssed formation July lo Running
and rife fire succeeded in safely bringing back his lines the
wounded BY the time he into the Chateau They drive he
with boche. They him. the boys
say Showers the hospital
his regiment take conspicuous in the St Me drive
the Argonn he distinguished himself the attack Of the Cote
-Chaon Hill 288 Through all the and battles of his
made soldier of leader of marked
ability all whose brilliant daring has been inspiration to
his men," reads his citation #
(
Omaha daily bee., 1919-06-15
A Disheartening Surpris'

They had been engaged for full 80
minutes by the cuckoo clock. II
have surprise in store for you.
Alfred, DEAR" she said. i can cook
as we'll as can play the piano"
"That being the case, darling" he
replied, Eve had better live in a
boarding house, Edinburgh Scots
man,
Omaha daily bee., 1919-06-15

MONDAY-4s-lb. sack Best High
Grade Flour .................$3 .$3.l6
z4-lb sack Best High-Grade Flour
~ .s.........'... .pl.oO
10 lbs. Best Pure Can Granuiated
sugar ................... ..V0c
10 bars Laundry Soap .......... $50
8 lbs. Best White or Yellow Corn
meal ............... .xoc
lbs. Best Chick Feed, for young
or old ...................
Why pay 10c lb. for package oats
when you can buy the best In
bulk for, per b............ Be
Fancy Japan Rice. per lb. ........ lie
The Best Domestic Macaroni, Spa
ghetti or Egg Noodles. pkg. .7Ac
Corn Flakes, pkg. ...7Jxc
Large bottle Fancy Assorted
F'ckies ."..'.........s. ...zoc
Omaha daily bee., 1919-06-15

cans Sunbrfght Cleanser. s5c
The Finest. Freshest and Most
Complete Line Of
DRIED FRUITS AND NUTS
IN THE CITY
WE ARE STILL SELLING COFFEE
AND TEA AT THE OLD PRICES.
Our famous Golden Santos Coffee.
per 10. sC&c
Diamond H Blend Coffee. per lb. .35c
II, B, C, Special Blend, h.. :. .37Hc
NJ. & J. Blend. nothing finer, no
matter what you pay. lb...... 40c
Choice Sun Dried. Basket Fired
or English Breakfast Tea. ib. SOC
Fancy Basket Fired Oolong. Cey-
Ion or Gunpowder Tea. lb..... .59c
res hest Tea Sitting. h......... .29c
Breakfast Cocoa, per lb.......... .s5c
Omaha daily bee., 1919-06-15
Governor Of Washington
Dies After Lima Illness

Seattle. Wash, June 14.-Ernest
Lister, governor of Washington.
died here today. He had been Ill for
several months.
Omaha daily bee., 1919-06-15

The barony Of Ros, dating from
1864 and believed to be the oldest
English barony in existence. is held
BY a woman in her own right.
Omaha daily bee., 1919-06-15

The cotton trade in Great Britain
hRx smployi eysi os QQQ nfQe|b 4
Omaha daily bee., 1919-06-15
Make Your Own Bread-It Pays
One pund Sack of Flour Will Make oaves of Bread

Large Jars Pure Fruit Preserves, $50
Large bottle Monarch Pure Tomato
CatSup ..........s...... xSC
No. 2 can Early juno Peas Fancy
Sweet Sugar Corn or Ripe
tomatoes ....s.ssss.......... .lZMc
The Best No. 1 Navy Beans, ib. .loc
Yeast Foam. pkg. e
No. ; can Golden Pumpkin. HON.
my or Kraut ...........,,,,ll lie
Tall can Fancy Pink Salmon. -, .sOc
Tall can Fancy Red, Salmon. :. .4Sc
Tall can Fancy Fresh Mackerel, .I0c
Tall can Pet or Carnation MIX. I5c
Tall can Wilson or Elkhorn Milk, .lAc
Snider's or CampbelPs Soups,
per n ................. l2he
Kamo Assorted Soups, can, .i0c
5.lb. ca Golden Table Syrup. 39e
cans Old Dutch Cleanser. csc
Omaha daily bee., 1919-06-15

THE VEGETABLE AND FRUIT
MARKET OF OMAHA.
S punches fresh Radishes. 30
3 punches fresh Onions. s............,....5 Sc
punches fresh Turnips. ...............5e Sc
Fresh Peas. per quart. rt...............7hc
lunches fresh Rhubarb. .............1 loo
Fresh Cabbage. per pound ........... &c
punches fresh Beets. s................ lOc
heads fresh Leaf Lettuce. ............ Sc
New Potatoes. lbs. s...................2 25c
Fresh Spinach, peck. k................,1O loo
Fancy Ripe Tomatoes. h.. .121zc
Large Juicy Lemons doz. ...... .30c-35c
Strawberries. Gooseberries, Black Rasp-
berries, Peaches. Bananas, etc. at the
Lowest Market Prices.
4 basket crates Fancy Aprcots. 49,. .S2.H