IB
107TH CONGRESS
1ST SESSION
H. R. 2647
IN THE HOUSE OF REPRESENTATIVES
JULY 31, 2001
Ordered to be printed with the amendments of the Senate numbered
AN ACT
Making appropriations for the Legislative Branch for the
fiscal year ending September 30, 2002, and for other
purposes.
Be it enacted by the Senate and House of Representa-
tives of the United States of America in Congress assembled,
That the following sums are appropriated, out of any
money in the Treasury not otherwise appropriated, for the
Legislative Branch for the fiscal year ending September
30, 2002, and for other purposes, namely:
TITLE I—CONGRESSIONAL OPERATIONS
Ω1æSENATE
EXPENSE ALLOWANCES
For expense allowances of the Vice President, $10,000;
the President Pro Tempore of the Senate, $10,000; Majority
Leader of the Senate, $10,000; Minority Leader of the Sen-
HR 2647 PP
ate, $10,000; Majority Whip of the Senate, $5,000; Minority
Whip of the Senate, $5,000; and Chairmen of the Majority
and Minority Conference Committees, $3,000 for each
Chairman; and Chairmen of the Majority and Minority
Policy Committees, $3,000 for each Chairman; in all,
$62,000.
REPRESENTATION ALLOWANCES FOR THE MAJORITY AND
MINORITY LEADERS
For representation allowances of the Majority and Mi-
nority Leaders of the Senate, $15,000 for each such Leader;
in all, $30,000.
SALARIES, OFFICERS AND EMPLOYEES
For compensation of officers, employees, and others as
authorized by law, including agency contributions,
$104,039,000, which shall be paid from this appropriation
without regard to the below limitations, as follows:
OFFICE OF THE VICE PRESIDENT
For the Office of the Vice President, $1,867,000.
OFFICE OF THE PRESIDENT PRO TEMPORE
For the Office of the President Pro Tempore, $473,000.
OFFICES OF THE MAJORITY AND MINORITY LEADERS
For Offices of the Majority and Minority Leaders,
$2,868,000.
HR 2647 PP
OFFICES OF THE MAJORITY AND MINORITY WHIPS
For Offices of the Majority and Minority Whips,
$1,912,000.
COMMITTEE ON APPROPRIATIONS
For salaries of the Committee on Appropriations,
$9,875,000.
CONFERENCE COMMITTEES
For the Conference of the Majority and the Conference
of the Minority, at rates of compensation to be fixed by the
Chairman of each such committee, $1,250,000 for each such
committee; in all, $2,500,000.
OFFICES OF THE SECRETARIES OF THE CONFERENCE OF
THE MAJORITY AND THE CONFERENCE OF THE MINORITY
For Offices of the Secretaries of the Conference of the
Majority and the Conference of the Minority, $618,000.
POLICY COMMITTEES
For salaries of the Majority Policy Committee and the
Minority Policy Committee, $1,275,000 for each such com-
mittee; in all, $2,550,000.
OFFICE OF THE CHAPLAIN
For Office of the Chaplain, $301,000.
OFFICE OF THE SECRETARY
For Office of the Secretary, $15,424,000.
HR 2647 PP
OFFICE OF THE SERGEANT AT ARMS AND DOORKEEPER
For Office of the Sergeant at Arms and Doorkeeper,
$39,082,000.
OFFICES OF THE SECRETARIES FOR THE MAJORITY AND
MINORITY
For Offices of the Secretary for the Majority and the
Secretary for the Minority, $1,350,000.
AGENCY CONTRIBUTIONS AND RELATED EXPENSES
For agency contributions for employee benefits, as au-
thorized by law, and related expenses, $25,219,000.
OFFICE OF THE LEGISLATIVE COUNSEL OF THE SENATE
For salaries and expenses of the Office of the Legisla-
tive Counsel of the Senate, $4,306,000.
OFFICE OF SENATE LEGAL COUNSEL
For salaries and expenses of the Office of Senate Legal
Counsel, $1,109,000.
EXPENSE ALLOWANCES OF THE SECRETARY OF THE SEN-
ATE, SERGEANT AT ARMS AND DOORKEEPER OF THE
SENATE, AND SECRETARIES FOR THE MAJORITY AND
MINORITY OF THE SENATE
For expense allowances of the Secretary of the Senate,
$3,000; Sergeant at Arms and Doorkeeper of the Senate,
$3,000; Secretary for the Majority of the Senate, $3,000;
Secretary for the Minority of the Senate, $3,000; in all,
$12,000.
HR 2647 PP
CONTINGENT EXPENSES OF THE SENATE
INQUIRIES AND INVESTIGATIONS
For expenses of inquiries and investigations ordered
by the Senate, or conducted pursuant to section 134(a) of
Public Law 601, Seventy-ninth Congress, as amended, sec-
tion 112 of Public Law 96–304 and Senate Resolution 281,
agreed to March 11, 1980, $107,264,000.
EXPENSES OF THE UNITED STATES SENATE CAUCUS ON
INTERNATIONAL NARCOTICS CONTROL
For expenses of the United States Senate Caucus on
International Narcotics Control, $370,000.
SECRETARY OF THE SENATE
For expenses of the Office of the Secretary of the Sen-
ate, $8,571,000, of which $7,000,000 shall remain available
until expended.
SERGEANT AT ARMS AND DOORKEEPER OF THE SENATE
For expenses of the Office of the Sergeant at Arms and
Doorkeeper of the Senate, $95,904,000, of which $8,654,000
shall remain available until September 30, 2004, and of
which $11,354,000 shall remain available until expended.
MISCELLANEOUS ITEMS
For miscellaneous items, $11,274,000.
SENATORS’ OFFICIAL PERSONNEL AND OFFICE EXPENSE
ACCOUNT
For Senators’ Official Personnel and Office Expense
Account, $270,494,000.
HR 2647 PP
OFFICIAL MAIL COSTS
For expenses necessary for official mail costs of the
Senate, $300,000.
MAILINGS FOR TOWN MEETINGS
For mailings of postal patron postcards by Members
for the purpose of providing notice of a town meeting by
a Member in a county (or equivalent unit of local govern-
ment) with a population of less than 50,000 that the Mem-
ber will personally attend to be allotted as requested,
$3,000,000, subject to authorization: Provided, That any
amount allocated to a Member for such mailing under this
paragraph shall not exceed 50 percent of the cost of the
mailing and the remaining costs shall be paid by the Mem-
ber from other funds available to the Member.
ADMINISTRATIVE PROVISIONS
SECTION 1. (a) Section 101(a) of the Supplemental
Appropriations Act, 1977 (2 U.S.C. 61h–6(a)) is amended
in the first sentence by striking ‘‘four individual consult-
ants’’ and inserting ‘‘six individual consultants’’, and is
amended in the second sentence by striking ‘‘one consult-
ant’’ and inserting ‘‘not more than two individual consult-
ants’’.
(b) This section shall apply with respect to fiscal year
2002 and each fiscal year thereafter.
SEC. 2. STUDENT LOAN REPAYMENTS. (a) DEFINI-
TIONS.—In this section:
HR 2647 PP
(1) EMPLOYEE OF THE SENATE.—The term ‘‘em-
ployee of the Senate’’ has the meaning given the term
in section 101 of the Congressional Accountability Act
of 1995 (2 U.S.C. 1301).
(2) EMPLOYING OFFICE.—The term ‘‘employing
office’’ means the employing office, as defined in such
section 101, of an employee of the Senate.
(3) STUDENT LOAN.—The term ‘‘student loan’’
has the meaning given the term in section 5379 of
title 5, United States Code.
(b) STUDENT LOAN REPAYMENT PROGRAM.—The head
of an employing office may, in order to recruit or retain
highly qualified personnel, establish a program under which
the office may agree to repay (by direct payments on behalf
of an employee of the Senate) any student loan previously
taken out by such employee.
(c) ADMINISTRATION.—
(1) IN GENERAL.—The head of an employing of-
fice shall carry out the program in accordance with
the provisions of subsections (b) through (d) and sub-
section (f) of section 5379 of title 5, United States
Code.
(2) APPLICATION.—For purposes of this section,
references in such provisions—
HR 2647 PP
(A) to an agency shall be considered to be
references to an employing office; and
(B) to an employee shall be considered to be
references to an employee of the Senate.
(d) AUTHORIZATION OF APPROPRIATIONS.—There are
authorized to be appropriated to carry out this section such
sums as may be necessary.
(e) EFFECTIVE DATE.—This section shall apply to fis-
cal year 2002 and each fiscal year thereafter.
SEC. 3. (a) Agency contributions for employees whose
salaries are disbursed by the Secretary of the Senate from
the appropriations account ‘‘Expenses of the United States
Senate Caucus on International Narcotics Control’’ under
the heading ‘‘Congressional Operations’’ shall be paid from
the Senate appropriations account for ‘‘Salaries, Officers
and Employees’’.
(b) This section shall apply to pay periods beginning
on or after October 1, 2001.
SEC. 4. (a) Section 5(a) under the subheading ‘‘ADMIN-
ISTRATIVE
PROVISIONS’’ under the heading ‘‘SENATE’’
under title I of the Legislative Branch Appropriations Act,
1996 (2 U.S.C. 58a note) is amended by striking ‘‘invoice
ends’’ and inserting ‘‘invoice begins’’.
HR 2647 PP
(b) The amendment made by subsection (a) shall take
effect on October 1, 2001, and shall apply to base service
periods beginning on or after that date.
SEC. 5. (a) Section 120 of Public Law 97–51 (2 U.S.C.
61g–6) is amended in the first sentence by striking
‘‘$75,000’’ and inserting ‘‘$100,000’’.
(b) This section shall apply with respect to fiscal year
2002 and each fiscal year thereafter.
SEC. 6. Effective on and after October 1, 2001, each
of the dollar amounts contained in the table under section
105(d)(1)(A) of the Legislative Branch Appropriations Act,
1968 (2 U.S.C. 61–1(d)(1)(A)) shall be deemed to be the
dollar amounts in that table, as adjusted by law and in
effect on September 30, 2001, increased by an additional
$50,000 each.
HOUSE OF REPRESENTATIVES
SALARIES AND EXPENSES
For salaries and expenses of the House of Represent-
atives, $882,100,000, as follows:
HOUSE LEADERSHIP OFFICES
For salaries and expenses, as authorized by law,
$15,910,000, 
including: 
Office 
of 
the 
Speaker,
$1,866,000, including $25,000 for official expenses of the
Speaker; Office of the Majority Floor Leader, $1,830,000,
including $10,000 for official expenses of the Majority
HR 2647 PP
Leader; Office of the Minority Floor Leader, $2,224,000,
including $10,000 for official expenses of the Minority
Leader; Office of the Majority Whip, including the Chief
Deputy Majority Whip, $1,562,000, including $5,000 for
official expenses of the Majority Whip; Office of the Mi-
nority Whip, including the Chief Deputy Minority Whip,
$1,168,000, including $5,000 for official expenses of the
Minority Whip; Speaker’s Office for Legislative Floor Ac-
tivities, $431,000; Republican Steering Committee,
$806,000; Republican Conference, $1,342,000; Demo-
cratic Steering and Policy Committee, $1,435,000; Demo-
cratic Caucus, $713,000; nine minority employees,
$1,293,000; training and program development—major-
ity, $290,000; training and program development—minor-
ity, $290,000; and Cloakroom Personnel—majority,
$330,000; and minority $330,000.
MEMBERS’ REPRESENTATIONAL ALLOWANCES
INCLUDING MEMBERS’ CLERK HIRE, OFFICIAL
EXPENSES OF MEMBERS, AND OFFICIAL MAIL
For Members’ representational allowances, including
Members’ clerk hire, official expenses, and official mail,
$479,472,000.
HR 2647 PP
COMMITTEE EMPLOYEES
STANDING COMMITTEES, SPECIAL AND SELECT
For salaries and expenses of standing committees,
special and select, authorized by House resolutions,
$104,514,000: Provided, That such amount shall remain
available for such salaries and expenses until December
31, 2002.
COMMITTEE ON APPROPRIATIONS
For salaries and expenses of the Committee on Ap-
propriations, $23,002,000, including studies and examina-
tions of executive agencies and temporary personal serv-
ices for such committee, to be expended in accordance with
section 202(b) of the Legislative Reorganization Act of
1946 and to be available for reimbursement to agencies
for services performed: Provided, That such amount shall
remain available for such salaries and expenses until De-
cember 31, 2002.
SALARIES, OFFICERS AND EMPLOYEES
For compensation and expenses of officers and em-
ployees, as authorized by law, $101,766,000, including:
for salaries and expenses of the Office of the Clerk, includ-
ing not more than $11,000, of which not more than
$10,000 is for the Family Room, for official representa-
tion and reception expenses, $15,408,000; for salaries and
expenses of the Office of the Sergeant at Arms, including
HR 2647 PP
the position of Superintendent of Garages, and including
not more than $750 for official representation and recep-
tion expenses, $4,139,000; for salaries and expenses of the
Office of the Chief Administrative Officer, $67,495,000,
of which $3,525,000 shall remain available until expended,
including $31,510,000 for salaries, expenses and tem-
porary personal services of House Information Resources,
of which $31,390,000 is provided herein: Provided, That
of the amount provided for House Information Resources,
$8,656,000 shall be for net expenses of telecommuni-
cations: Provided further, That House Information Re-
sources is authorized to receive reimbursement from Mem-
bers of the House of Representatives and other govern-
mental entities for services provided and such reimburse-
ment shall be deposited in the Treasury for credit to this
account; for salaries and expenses of the Office of the In-
spector General, $3,756,000; for salaries and expenses of
the Office of General Counsel, $894,000; for the Office
of the Chaplain, $144,000; for salaries and expenses of
the Office of the Parliamentarian, including the Parlia-
mentarian and $2,000 for preparing the Digest of Rules,
$1,344,000; for salaries and expenses of the Office of the
Law Revision Counsel of the House, $2,107,000; for sala-
ries and expenses of the Office of the Legislative Counsel
of the House, $5,456,000; for salaries and expenses of the
HR 2647 PP
Corrections Calendar Office, $883,000; and for other au-
thorized employees, $140,000.
ALLOWANCES AND EXPENSES
For allowances and expenses as authorized by House
resolution or law, $157,436,000, including: supplies, mate-
rials, administrative costs and Federal tort claims,
$3,379,000; official mail for committees, leadership of-
fices, and administrative offices of the House, $410,000;
Government contributions for health, retirement, Social
Security, 
and 
other 
applicable 
employee 
benefits,
$152,957,000; and miscellaneous items including pur-
chase, exchange, maintenance, repair and operation of
House motor vehicles, interparliamentary receptions, and
gratuities to heirs of deceased employees of the House,
$690,000.
CHILD CARE CENTER
For salaries and expenses of the House of Represent-
atives Child Care Center, such amounts as are deposited
in the account established by section 312(d)(1) of the Leg-
islative Branch Appropriations Act, 1992 (40 U.S.C.
184g(d)(1)), subject to the level specified in the budget
of the Center, as submitted to the Committee on Appro-
priations of the House of Representatives.
HR 2647 PP
ADMINISTRATIVE PROVISIONS
SEC. 101. (a) Effective October 1, 2001, the fol-
lowing four majority positions shall be transferred from
the Clerk to the Speaker:
(1) The position of chief of floor service.
(2) Two positions of assistant floor chief.
(3) One position of cloakroom attendant.
(b) Effective October 1, 2001, the following four mi-
nority positions shall be transferred from the Clerk to the
minority leader:
(1) The position of chief of floor service.
(2) Two positions of assistant floor chief.
(3) One position of cloakroom attendant.
(c) Each individual who is an incumbent of a position
transferred by subsection (a) or subsection (b) at the time
of the transfer shall remain subject to the House Employ-
ees Position Classification Act (2 U.S.C. 290 et seq.), ex-
cept that the authority of the Clerk and the committee
under the Act shall be exercised—
(1) by the Speaker, in the case of an individual
in a position transferred under subsection (a); and
(2) by the minority leader, in the case of an in-
dividual in a position transferred under subsection
(b).
HR 2647 PP
of the Senate or the Sergeant at Arms of the House of
Representatives designated by the Chairman of the Board,
$11,081,000, to be disbursed by the Chief of the Capitol
Police or the Chief’s delegee: Provided, That, notwith-
standing any other provision of law, the cost of basic train-
ing for the Capitol Police at the Federal Law Enforcement
Training Center for fiscal year 2002 shall be paid by the
Secretary of the Treasury from funds available to the De-
partment of the Treasury.
ADMINISTRATIVE PROVISIONS
SEC. 105. Amounts appropriated for fiscal year 2002
for the Capitol Police may be transferred between the
headings ‘‘SALARIES’’ and ‘‘GENERAL EXPENSES’’ upon
the approval of—
(1) the Committee on Appropriations of the
House of Representatives, in the case of amounts
transferred from the appropriation provided to the
Sergeant at Arms of the House of Representatives
under the heading ‘‘SALARIES’’;
(2) the Committee on Appropriations of the
Senate, in the case of amounts transferred from the
appropriation provided to the Sergeant at Arms and
Doorkeeper of the Senate under the heading ‘‘SALA-
RIES’’; and
HR 2647 PP
(3) the Committees on Appropriations of the
Senate and the House of Representatives, in the
case of other transfers.
CAPITOL GUIDE SERVICE AND SPECIAL SERVICES
OFFICE
For salaries and expenses of the Capitol Guide Serv-
ice and Special Services Office, $2,512,000, to be dis-
bursed by the Secretary of the Senate: Provided, That no
part of such amount may be used to employ more than
43 individuals: Provided further, That the Capitol Guide
Board is authorized, during emergencies, to employ not
more than two additional individuals for not more than
120 days each, and not more than 10 additional individ-
uals for not more than 6 months each, for the Capitol
Guide Service.
STATEMENTS OF APPROPRIATIONS
For the preparation, under the direction of the Com-
mittees on Appropriations of the Senate and the House
of Representatives, of the statements for the first session
of the One Hundred Seventh Congress, showing appro-
priations made, indefinite appropriations, and contracts
authorized, together with a chronological history of the
regular appropriations bills as required by law, $30,000,
to be paid to the persons designated by the chairmen of
such committees to supervise the work.
HR 2647 PP
OFFICE OF COMPLIANCE
SALARIES AND EXPENSES
For salaries and expenses of the Office of Compli-
ance, as authorized by section 305 of the Congressional
Accountability Act of 1995 (2 U.S.C. 1385), $2,059,000,
of which $254,000 shall remain available until September
30, 2003.
CONGRESSIONAL BUDGET OFFICE
SALARIES AND EXPENSES
For salaries and expenses necessary to carry out the
provisions of the Congressional Budget Act of 1974 (Pub-
lic Law 93–344), including not more than $3,000 to be
expended on the certification of the Director of the Con-
gressional Budget Office in connection with official rep-
resentation and reception expenses, $30,780,000: Pro-
vided, That no part of such amount may be used for the
purchase or hire of a passenger motor vehicle.
ADMINISTRATIVE PROVISIONS
SEC. 106. (a) The Director of the Congressional
Budget Office may, by regulation, make applicable such
provisions of chapter 41 of title 5, United States Code,
as the Director determines necessary to provide hereafter
for training of individuals employed by the Congressional
Budget Office.
HR 2647 PP
(b) The implementing regulations shall provide for
training that, in the determination of the Director, is con-
sistent with the training provided by agencies subject to
chapter 41 of title 5, United States Code.
(c) Any recovery of debt owed to the Congressional
Budget Office under this section and its implementing reg-
ulations shall be credited to the appropriations account
available for salaries and expenses of the Office at the time
of recovery.
SEC. 107. Section 105(a) of the Legislative Branch
Appropriations Act, 1997 (2 U.S.C. 606(a)), is amended
by striking ‘‘or discarding.’’ and inserting ‘‘sale, trade-in,
or discarding.’’, and by adding at the end the following:
‘‘Amounts received for the sale or trade-in of personal
property shall be credited to funds available for the oper-
ations of the Congressional Budget Office and be available
for the costs of acquiring the same or similar property.
Such funds shall be available for such purposes during the
fiscal year in which received and the following fiscal
year.’’.
ARCHITECT OF THE CAPITOL
CAPITOL BUILDINGS AND GROUNDS
GENERAL AND ADMINISTRATION
SALARIES AND EXPENSES
For salaries for the Architect of the Capitol, the As-
sistant Architect of the Capitol, and other personal serv-
HR 2647 PP
ices, at rates of pay provided by law; for surveys and stud-
ies in connection with activities under the care of the Ar-
chitect of the Capitol; for all necessary expenses for the
general and administrative support of the operations
under the Architect of the Capitol including the Botanic
Garden; electrical substations of the Capitol, Senate and
House office buildings, and other facilities under the juris-
diction of the Architect of the Capitol; including fur-
nishings and office equipment; including not more than
$1,000 for official reception and representation expenses,
to be expended as the Architect of the Capitol may ap-
prove; for purchase or exchange, maintenance, and oper-
ation of a passenger motor vehicle; and not to exceed
$30,000 for attendance, when specifically authorized by
the Architect of the Capitol, at meetings or conventions
in connection with subjects related to work under the Ar-
chitect of the Capitol, $46,705,000, of which $3,414,000
shall remain available until expended.
MINOR CONSTRUCTION
For minor construction (as established under section
108 of this Act), $9,482,000, to remain available until ex-
pended, to be used in accordance with the terms and con-
ditions described in such section.
HR 2647 PP
CAPITOL BUILDINGS
For all necessary expenses for the maintenance, care
and operation of the Capitol $17,674,000, of which
$6,267,000 shall remain available until expended.
CAPITOL GROUNDS
For all necessary expenses for care and improvement
of grounds surrounding the Capitol, the Senate and House
office buildings, and the Capitol Power Plant, $6,904,000,
of which $100,000 shall remain available until expended.
JOINT ITEMS
For Joint Committees, as follows:
JOINT ECONOMIC COMMITTEE
For salaries and expenses of the Joint Economic Com-
mittee, $3,424,000, to be disbursed by the Secretary of the
Senate.
JOINT COMMITTEE ON TAXATION
For salaries and expenses of the Joint Committee on
Taxation, $6,733,000, to be disbursed by the Chief Adminis-
trative Officer of the House.
For other joint items, as follows:
OFFICE OF THE ATTENDING PHYSICIAN
For medical supplies, equipment, and contingent ex-
penses of the emergency rooms, and for the Attending Physi-
cian and his assistants, including: (1) an allowance of
$1,500 per month to the Attending Physician; (2) an allow-
HR 2647 PP
ance of $500 per month each to three medical officers while
on duty in the Office of the Attending Physician; (3) an
allowance of $500 per month to one assistant and $400 per
month each not to exceed 11 assistants on the basis here-
tofore provided for such assistants; and (4) $1,159,904 for
reimbursement to the Department of the Navy for expenses
incurred for staff and equipment assigned to the Office of
the Attending Physician, which shall be advanced and cred-
ited to the applicable appropriation or appropriations from
which such salaries, allowances, and other expenses are pay-
able and shall be available for all the purposes thereof,
$1,765,000, to be disbursed by the Chief Administrative Of-
ficer of the House.
CAPITOL POLICE BOARD
CAPITOL POLICE
SALARIES
For the Capitol Police Board for salaries of officers,
members, and employees of the Capitol Police, including
overtime, hazardous duty pay differential, clothing allow-
ance of not more than $600 each for members required to
wear civilian attire, and Government contributions for
health, retirement, Social Security, and other applicable
employee benefits, $112,922,000, of which $55,296,000 is
provided to the Sergeant at Arms of the House of Represent-
atives, to be disbursed by the Chief Administrative Officer
HR 2647 PP
of the House, and $57,626,000 is provided to the Sergeant
at Arms and Doorkeeper of the Senate, to be disbursed by
the Secretary of the Senate: Provided, That, of the amounts
appropriated under this heading, such amounts as may be
necessary may be transferred between the Sergeant at Arms
of the House of Representatives and the Sergeant at Arms
and Doorkeeper of the Senate, upon approval of the Com-
mittee on Appropriations of the House of Representatives
and the Committee on Appropriations of the Senate.
GENERAL EXPENSES
For the Capitol Police Board for necessary expenses
of the Capitol Police, including motor vehicles, communica-
tions and other equipment, security equipment and instal-
lation, uniforms, weapons, supplies, materials, training,
medical services, forensic services, stenographic services,
personal and professional services, the employee assistance
program, not more than $2,000 for the awards program,
postage, telephone service, travel advances, relocation of in-
structor and liaison personnel for the Federal Law Enforce-
ment Training Center, and $85 per month for extra services
performed for the Capitol Police Board by an employee of
the Sergeant at Arms of the Senate or the House of Rep-
resentatives designated by the Chairman of the Board,
$12,394,000, to be disbursed by the Capitol Police Board
or their delegee: Provided, That, notwithstanding any other
HR 2647 PP
provision of law, the cost of basic training for the Capitol
Police at the Federal Law Enforcement Training Center for
fiscal year 2002 shall be paid by the Secretary of the Treas-
ury from funds available to the Department of the Treas-
ury.
ADMINISTRATIVE PROVISION
SEC. 101. Amounts appropriated for fiscal year 2002
for the Capitol Police Board for the Capitol Police may be
transferred between the headings ‘‘SALARIES’’ and ‘‘GEN-
ERAL EXPENSES’’ upon the approval of—
(1) the Committee on Appropriations of the
House of Representatives, in the case of amounts
transferred from the appropriation provided to the
Sergeant at Arms of the House of Representatives
under the heading ‘‘SALARIES’’;
(2) the Committee on Appropriations of the Sen-
ate, in the case of amounts transferred from the ap-
propriation provided to the Sergeant at Arms and
Doorkeeper of the Senate under the heading ‘‘SALA-
RIES’’; and
(3) the Committees on Appropriations of the
Senate and the House of Representatives, in the case
of other transfers.
HR 2647 PP
CAPITOL GUIDE SERVICE AND SPECIAL SERVICES OFFICE
For salaries and expenses of the Capitol Guide Service
and Special Services Office, $2,512,000, to be disbursed by
the Secretary of the Senate: Provided, That no part of such
amount may be used to employ more than 43 individuals:
Provided further, That the Capitol Guide Board is author-
ized, during emergencies, to employ not more than two ad-
ditional individuals for not more than 120 days each, and
not more than 10 additional individuals for not more than
6 months each, for the Capitol Guide Service.
STATEMENTS OF APPROPRIATIONS
For the preparation, under the direction of the Com-
mittees on Appropriations of the Senate and the House of
Representatives, of the statements for the first session of the
One Hundred Seventh Congress, showing appropriations
made, indefinite appropriations, and contracts authorized,
together with a chronological history of the regular appro-
priations bills as required by law, $30,000, to be paid to
the persons designated by the chairmen of such committees
to supervise the work.
OFFICE OF COMPLIANCE
SALARIES AND EXPENSES
For salaries and expenses of the Office of Compliance,
as authorized by section 305 of the Congressional Account-
ability Act of 1995 (2 U.S.C. 1385), $2,059,000.
HR 2647 PP
CONGRESSIONAL BUDGET OFFICE
SALARIES AND EXPENSES
For salaries and expenses necessary to carry out the
provisions of the Congressional Budget Act of 1974 (Public
Law 93–344), including not more than $3,000 to be ex-
pended on the certification of the Director of the Congres-
sional Budget Office in connection with official representa-
tion and reception expenses, $30,680,000: Provided, That
no part of such amount may be used for the purchase or
hire of a passenger motor vehicle.
ADMINISTRATIVE PROVISIONS
SEC. 102. (a) The Director of the Congressional Budget
Office may, by regulation, make applicable such provisions
of chapter 41 of title 5, United States Code, as the Director
determines necessary to provide hereafter for training of in-
dividuals employed by the Congressional Budget Office.
(b) The implementing regulations shall provide for
training that, in the determination of the Director, is con-
sistent with the training provided by agencies subject to
chapter 41 of title 5, United States Code.
(c) Any recovery of debt owed to the Congressional
Budget Office under this section and its implementing regu-
lations shall be credited to the appropriations account
available for training employees of the Office at the time
of recovery.
HR 2647 PP
(d) This section shall apply to fiscal year 2002 and
each fiscal year thereafter.
SEC. 103. Section 105(a) of the Legislative Branch Ap-
propriations Act, 1996 (2 U.S.C. § 606(a)), is amended by
striking ‘‘or discarding.’’ and inserting ‘‘sale, trade-in, or
discarding.’’, and by adding at the end the following:
‘‘Amounts received for the sale or trade-in of personal prop-
erty shall be credited to funds available for the operations
of the Congressional Budget Office and be available for the
costs of acquiring the same or similar property. Such funds
shall be available for such purposes during the fiscal year
in which received and the following fiscal year.’’.
SEC. 104. (a) The Director of the Congressional Budget
Office may, in order to recruit or retain qualified personnel,
establish and maintain hereafter a program under which
the Office may agree to repay (by direct payments on behalf
of the employee) all or a portion of any student loan pre-
viously taken out by such employee.
(b) The Director may, by regulation, make applicable
such provisions of section 5379 of title 5, United States
Code as the Director determines necessary to provide for
such program.
(c) The regulations shall provide the amount paid by
the Office may not exceed—
HR 2647 PP
(1) $6,000 for any employee in any calendar
year; or
(2) a total of $40,000 in the case of any em-
ployee.
(d) The Office may not reimburse an employee for any
repayments made by such employee prior to the Office en-
tering into an agreement under this section with such em-
ployee.
(e) Any amount repaid by, or recovered from, an indi-
vidual under this section and its implementing regulations
shall be credited to the appropriation account available for
salaries and expenses of the Office at the time of repayment
or recovery.
(f) This section shall apply to fiscal year 2002 and
each fiscal year thereafter.
ARCHITECT OF THE CAPITOL
CAPITOL BUILDINGS AND GROUNDS
CAPITOL BUILDINGS
SALARIES AND EXPENSES
For salaries for the Architect of the Capitol, the Assist-
ant Architect of the Capitol, and other personal services,
at rates of pay provided by law; for surveys and studies
in connection with activities under the care of the Architect
of the Capitol; for all necessary expenses for the mainte-
nance, care and operation of the Capitol and electrical sub-
HR 2647 PP
stations of the Senate and House office buildings under the
jurisdiction of the Architect of the Capitol, including fur-
nishings and office equipment, including not more than
$1,000 for official reception and representation expenses, to
be expended as the Architect of the Capitol may approve;
for purchase or exchange, maintenance and operation of a
passenger motor vehicle; and not to exceed $20,000 for at-
tendance, when specifically authorized by the Architect of
the Capitol, at meetings or conventions in connection with
subjects related to work under the Architect of the Capitol,
$54,000,000, of which $5,000,000 shall remain available
until expended: Provided, That the Architect of the Capitol,
in consultation with the Comptroller General or his des-
ignee, shall appoint a Chief Financial Officer within 90
days after the date of enactment of this Act: Provided fur-
ther, That notwithstanding any other provision of law and
subject to the availability of appropriations, the Architect
of the Capitol is authorized to secure, through multi-year
rental, lease, or other appropriate agreement, the property
located at 67 K Street, S.W., Washington, D.C., for use of
Legislative Branch agencies, and to incur any necessary in-
cidental expenses including maintenance, alterations, and
repairs in connection therewith: Provided further, That in
connection with the property referred to under the preceding
proviso, the Architect of the Capitol is authorized to expend
HR 2647 PP
funds appropriated to the Architect of the Capitol for the
purpose of the operations and support of Legislative Branch
agencies, including the United States Capitol Police, as
may be required for that purpose.
CAPITOL GROUNDS
For all necessary expenses for care and improvement
of grounds surrounding the Capitol, the Senate and House
office buildings, and the Capitol Power Plant, $6,000,000.
SENATE OFFICE BUILDINGS
For all necessary expenses for the maintenance, care
and operation of Senate office buildings; and furniture and
furnishings to be expended under the control and super-
vision of the Architect of the Capitol, $47,500,000, of which
$3,400,000 shall remain available until expended.
HOUSE OFFICE BUILDINGS
For all necessary expenses for the maintenance, care
and operation of the House office buildings, $49,006,000,
of which $18,344,000 shall remain available until ex-
pended.
Ω3æCAPITOL POWER PLANT
For all necessary expenses for the maintenance, care
and operation of the Capitol Power Plant; lighting, heat-
ing, power (including the purchase of electrical energy)
and water and sewer services for the Capitol, Senate and
House office buildings, Library of Congress buildings, and
HR 2647 PP
the grounds about the same, Botanic Garden, Senate ga-
rage, and air conditioning refrigeration not supplied from
plants in any of such buildings; heating the Government
Printing Office and Washington City Post Office, and
heating and chilled water for air conditioning for the Su-
preme Court Building, the Union Station complex, the
Thurgood Marshall Federal Judiciary Building and the
Folger Shakespeare Library, expenses for which shall be
advanced or reimbursed upon request of the Architect of
the Capitol and amounts so received shall be deposited
into the Treasury to the credit of this appropriation,
$45,324,000, of which $100,000 shall remain available
until expended: Provided, That not more than $4,400,000
of the funds credited or to be reimbursed to this appro-
priation as herein provided shall be available for obligation
during fiscal year 2002.
ADMINISTRATIVE PROVISIONS
SEC. 108. (a) ESTABLISHMENT OF ACCOUNT FOR
MINOR CONSTRUCTION.—There is hereby established in
the Treasury of the United States an account for the Ar-
chitect of the Capitol to be known as ‘‘minor construction’’
(hereafter in this section referred to as the ‘‘account’’).
(b) USES OF FUNDS IN ACCOUNT.—Subject to sub-
section (c), funds in the account shall be used by the Ar-
chitect of the Capitol for land and building acquisition,
construction, repair, and alteration projects resulting from
HR 2647 PP
unforeseen and unplanned conditions in connection with
construction and maintenance activities under the jurisdic-
tion of the Architect (including the United States Botanic
Garden).
(c) PRIOR NOTIFICATION REQUIRED FOR OBLIGA-
TION.—The Architect of the Capitol may not obligate any
funds in the account with respect to a project unless, not
fewer than 21 days prior to the obligation, the Architect
provides notice of the obligation to—
(1) the Committee on Appropriations of the
House of Representatives, in the case of a project on
behalf of the House of Representatives;
(2) the Committee on Appropriations of the
Senate, in the case of a project on behalf of the Sen-
ate; or
(3) both the Committee on Appropriations of
the House of Representatives and the Committee on
Appropriations of the Senate, in the case of any
other project.
(d) EFFECTIVE DATE.—This section shall apply with
respect to fiscal year 2002 and each succeeding fiscal year.
SEC. 109. (a) ACQUISITION OF PROPERTY BY ARCHI-
TECT OF THE CAPITOL.—Notwithstanding any other pro-
vision of law, the Architect of the Capitol is authorized
to secure, subject to the availability of appropriated funds
HR 2647 PP
(through such agreement as the Architect considers appro-
priate), the property and facilities located at 67 K Street
Southwest in the District of Columbia (square 645, lot
814).
(b) USES AND CONTROL OF PROPERTY.—
(1) IN GENERAL.—The property and facilities
secured by the Architect under subsection (a) shall
be under the control of the Chief of the United
States Capitol Police and shall be used by the Chief
for the care and maintenance of vehicles of the
United States Capitol Police, in accordance with a
plan prepared by the Chief and approved by the
Committees on Appropriations of the House of Rep-
resentatives and Senate.
(2) ADDITIONAL USES PERMITTED.—In addi-
tion to the use described in paragraph (1), the Chief
of the United States Capitol Police may permit the
property and facilities secured by the Architect
under subsection (a) to be used for other purposes
by the United States Capitol Police, the House of
Representatives, the Senate, and the Architect of the
Capitol, subject to—
(A) the approval of the Committee on Ap-
propriations of the House of Representatives, in
HR 2647 PP
the case of use by the House of Representa-
tives;
(B) the approval of the Committee on Ap-
propriations of the Senate, in the case of use by
the Senate; or
(C) the approval of both the Committee on
Appropriations of the House of Representatives
and the Committee on Appropriations of the
Senate, in the case of use by the United States
Capitol Police or the Architect of the Capitol.
(c) EXPENSES.—
(1) IN GENERAL.—The Architect of the Capitol
shall be responsible for the costs of the necessary ex-
penses incidental to the use of the property and fa-
cilities described in subsection (a) (including pay-
ments under the lease), including expenses for main-
tenance, alterations, and repair of the property and
facilities, except that the Chief of the United States
Capitol Police shall be responsible for the costs of
any equipment, furniture, and furnishings used in
connection with the care and maintenance of vehicles
pursuant to subsection (b)(1).
(2) SOURCE OF FUNDS.—
(A) IN GENERAL.—The funds expended by
the Architect to carry out paragraph (1) in any
HR 2647 PP
fiscal year shall be derived solely from funds
appropriated to the Architect for the fiscal year
for purposes of the United States Capitol Po-
lice.
(B) USE OF CERTAIN 1999 FUNDS.—The
funds expended by the Architect to carry out
paragraph (1) may also be derived from funds
appropriated to the Architect in the Legislative
Branch Appropriations Act, 1999, under the
heading ‘‘ARCHITECT OF THE CAPITOL—
CAPITOL BUILDINGS AND GROUNDS—CAPITOL
BUILDINGS—SALARIES AND EXPENSES’’ for the
design of police security projects, which shall
remain available until expended.
(d) EFFECTIVE DATE.—This section shall take effect
on the date of enactment of this Act.
SEC. 110. (a) COMPENSATION OF CERTAIN POSI-
TIONS IN THE OFFICE OF THE ARCHITECT OF THE CAP-
ITOL.—In accordance with the authority described in sec-
tion 308(a) of the Legislative Branch Appropriations Act,
1988 (40 U.S.C. 166b–3a(a)), section 108 of the Legisla-
tive Branch Appropriations Act, 1991 (40 U.S.C. 166b–
3b) is amended—
(1) by striking subsections (a) and (b) and in-
serting the following:
HR 2647 PP
‘‘(a) The Architect of the Capitol may fix the rate
of basic pay for not more than 11 positions (of whom 1
shall be the project manager for the Capitol Visitor Center
and 1 shall be the project manager for the modification
of the Capitol Power Plant) at a rate not to exceed the
highest total rate of pay for the Senior Executive Service
under subchapter VIII of chapter 53 of title 5, United
States Code, for the locality involved.’’; and
(2) by redesignating subsection (c) as sub-
section (b).
(b) COMPREHENSIVE MANAGEMENT STUDY AND RE-
SPONSE.—
(1) STUDY BY COMPTROLLER GENERAL.—The
Comptroller General shall conduct a comprehensive
management study of the operations of the Architect
of the Capitol, and shall submit the study to the Ar-
chitect of the Capitol and the Committees on Appro-
priations of the House of Representatives and Sen-
ate.
(2) PLAN BY ARCHITECT IN RESPONSE.—The
Architect of the Capitol shall develop and submit to
the Committees referred to in paragraph (1) a man-
agement improvement plan which addresses the
study of the Comptroller General under paragraph
(1) and which indicates how the salary adjustments
HR 2647 PP
made by the amendments made by this section will
support such plan.
(c) EFFECTIVE DATE.—This section (other than sub-
section (b)) and the amendments made by this section
shall apply with respect to pay periods beginning on or
after the date on which the Committees on Appropriations
of the House of Representatives and Senate approve the
plan submitted by the Architect of the Capitol under sub-
section (b)(2).
SEC. 111. (a) LIQUIDATED DAMAGES.—The Archi-
tect of the Capitol may not enter into or administer any
construction contract with a value greater than $50,000
unless the contract includes a provision requiring the pay-
ment of liquidated damages in the amount determined
under subsection (b) in the event that completion of the
project is delayed because of the contractor.
(b) AMOUNT OF PAYMENT.—The amount of payment
required under a liquidated damages provision described
in subsection (a) shall be equal to the product of—
(1) the daily liquidated damage payment rate;
and
(2) the number of days by which the completion
of the project is delayed.
(c) DAILY LIQUIDATED DAMAGE PAYMENT RATE.—
HR 2647 PP
(1) IN GENERAL.—In subsection (b), the ‘‘daily
liquidated damage payment rate’’ means—
(A) $140, in the case of a contract with a
value
greater
than
$50,000
and
less
than
$100,000;
(B) $200, in the case of a contract with a
value equal to or greater than $100,000 and
equal to or less than $500,000; and
(C) the sum of $200 plus $50 for each
$100,000 increment by which the value of the
contract exceeds $500,000, in the case of a con-
tract with a value greater than $500,000.
(2) ADJUSTMENT IN RATE PERMITTED.—Not-
withstanding paragraph (1), the daily liquidated
damage payment rate may be adjusted by the con-
tracting officer involved to a rate greater or lesser
than the rate described in such paragraph if the con-
tracting officer makes a written determination that
the rate described does not accurately reflect the an-
ticipated damages which will be suffered by the
United States as a result of the delay in the comple-
tion of the contract.
(d) EFFECTIVE DATE.—This section shall apply with
respect to contracts entered into during fiscal year 2002
or any succeeding fiscal year.
HR 2647 PP
SEC. 112. (a) Notwithstanding any other provision
of law, the Architect of the Capitol may not reprogram
any funds with respect to any project or object class with-
out the approval of—
(1) the Committee on Appropriations of the
House of Representatives, in the case of a project or
object class within the House of Representatives;
(2) the Committee on Appropriations of the
Senate, in the case of a project or object class within
the Senate; or
(3) both the Committee on Appropriations of
the House of Representatives and the Committee on
Appropriations of the Senate, in the case of any
other project or object class.
(b) This section shall apply with respect to funds pro-
vided to the Architect of the Capitol before, on, or after
the date of the enactment of this Act.
SEC. 113. (a) LIMITATION.—(1) Except as provided
in paragraph (2), none of the funds provided by this Act
or any other Act may be used by the Architect of the Cap-
itol during fiscal year 2002 or any succeeding fiscal year
to employ any individual as a temporary employee within
a category of temporary employment which does not pro-
vide employees with the same eligibility for life insurance,
health insurance, retirement, and other benefits which is
HR 2647 PP
provided to temporary employees who are hired for a pe-
riod exceeding 1 year in length.
(2) Paragraph (1) shall not apply with respect to any
individual who is a temporary employee of the Senate Res-
taurant or a temporary employee who is hired for a total
of 120 days or less during any 5-year period.
(b) ALLOTMENT
AND ASSIGNMENT
OF PAY.—(1)
Section 5525 of title 5, United States Code, is amended
by adding at the end the following new sentence: ‘‘For
purposes of this section, the term ‘agency’ includes the
Office of the Architect of the Capitol.’’.
(2) The amendment made by paragraph (1) shall
apply with respect to pay periods beginning on or after
the date of the enactment of this Act.
LIBRARY OF CONGRESS
CONGRESSIONAL RESEARCH SERVICE
SALARIES AND EXPENSES
For necessary expenses to carry out the provisions
of section 203 of the Legislative Reorganization Act of
1946 (2 U.S.C. 166) and to revise and extend the Anno-
tated Constitution of the United States of America,
$81,454,000: Provided, That no part of such amount may
be used to pay any salary or expense in connection with
any publication, or preparation of material therefor (ex-
cept the Digest of Public General Bills), to be issued by
HR 2647 PP
the Library of Congress unless such publication has ob-
tained prior approval of either the Committee on House
Administration of the House of Representatives or the
Committee on Rules and Administration of the Senate.
GOVERNMENT PRINTING OFFICE
CONGRESSIONAL PRINTING AND BINDING
(INCLUDING TRANSFER OF FUNDS)
For authorized printing and binding for the Congress
and the distribution of Congressional information in any
format; printing and binding for the Architect of the Cap-
itol; expenses necessary for preparing the semimonthly
and session index to the Congressional Record, as author-
ized by law (44 U.S.C. 902); printing and binding of Gov-
ernment publications authorized by law to be distributed
to Members of Congress; and printing, binding, and dis-
tribution of Government publications authorized by law to
be
distributed
without
charge
to
the
recipient,
$81,000,000: Provided, That this appropriation shall not
be available for paper copies of the permanent edition of
the Congressional Record for individual Representatives,
Resident Commissioners or Delegates authorized under 44
U.S.C. 906: Provided further, That this appropriation
shall be available for the payment of obligations incurred
under the appropriations for similar purposes for pre-
ceding fiscal years: Provided further, That notwithstanding
HR 2647 PP
the 2-year limitation under section 718 of title 44, United
States Code, none of the funds appropriated or made
available under this Act or any other Act for printing and
binding and related services provided to Congress under
chapter 7 of title 44, United States Code, may be ex-
pended to print a document, report, or publication after
the 27-month period beginning on the date that such docu-
ment, report, or publication is authorized by Congress to
be printed, unless Congress reauthorizes such printing in
accordance with section 718 of title 44, United States
Code: Provided further, That any unobligated or unex-
pended balances in this account or accounts for similar
purposes for preceding fiscal years may be transferred to
the Government Printing Office revolving fund for car-
rying out the purposes of this heading, subject to the ap-
proval of the Committees on Appropriations of the House
of Representatives and Senate.
This title may be cited as the ‘‘Congressional Oper-
ations Appropriations Act, 2002’’.
TITLE II—OTHER AGENCIES
BOTANIC GARDEN
SALARIES AND EXPENSES
For all necessary expenses for the maintenance, care
and operation of the Botanic Garden and the nurseries,
buildings, grounds, and collections; and purchase and ex-
HR 2647 PP
change, maintenance, repair, and operation of a passenger
motor vehicle; all under the direction of the Joint Com-
mittee on the Library, $5,946,000: Provided, That this ap-
propriation shall not be available for any activities of the
National Garden: Provided further, That not more than
$25,000 of the amount appropriated under this heading
is available for official reception and representation ex-
penses in connection with the opening of the renovated
Botanic Garden Conservatory, upon approval by the
Speaker of the House of Representatives and the Presi-
dent Pro Tempore of the Senate.
LIBRARY OF CONGRESS
SALARIES AND EXPENSES
For necessary expenses of the Library of Congress
not otherwise provided for, including development and
maintenance of the Union Catalogs; custody and custodial
care of the Library buildings; special clothing; cleaning,
laundering and repair of uniforms; preservation of motion
pictures in the custody of the Library; operation and
maintenance of the American Folklife Center in the Li-
brary; preparation and distribution of catalog records and
other publications of the Library; hire or purchase of one
passenger motor vehicle; and expenses of the Library of
Congress Trust Fund Board not properly chargeable to
the income of any trust fund held by the Board,
HR 2647 PP
$304,692,000, of which not more than $6,500,000 shall
be derived from collections credited to this appropriation
during fiscal year 2002, and shall remain available until
expended, under the Act of June 28, 1902 (chapter 1301;
32 Stat. 480; 2 U.S.C. 150) and not more than $350,000
shall be derived from collections during fiscal year 2002
and shall remain available until expended for the develop-
ment and maintenance of an international legal informa-
tion database and activities related thereto: Provided,
That the Library of Congress may not obligate or expend
any funds derived from collections under the Act of June
28, 1902, in excess of the amount authorized for obliga-
tion or expenditure in appropriations Acts: Provided fur-
ther, That the total amount available for obligation shall
be reduced by the amount by which collections are less
than the $6,850,000: Provided further, That of the total
amount appropriated, $15,824,474 is to remain available
until expended for acquisition of books, periodicals, news-
papers, and all other materials including subscriptions for
bibliographic services for the Library, including $40,000
to be available solely for the purchase, when specifically
approved by the Librarian, of special and unique materials
for additions to the collections: Provided further, That of
the total amount appropriated, $1,517,903 is to remain
available until expended for the acquisition and partial
HR 2647 PP
support for implementation of an Integrated Library Sys-
tem (ILS): Provided further, That of the total amount ap-
propriated, $5,600,000 is to remain available until ex-
pended for the purpose of teaching educators how to incor-
porate the Library’s digital collections into school cur-
ricula and shall be transferred to the educational consor-
tium formed to conduct the ‘‘Joining Hands Across Amer-
ica: Local Community Initiative’’ project as approved by
the Library.
COPYRIGHT OFFICE
SALARIES AND EXPENSES
For necessary expenses of the Copyright Office,
$40,896,000, of which not more than $21,880,000, to re-
main available until expended, shall be derived from collec-
tions credited to this appropriation during fiscal year 2002
under 17 U.S.C. 708(d): Provided, That the Copyright Of-
fice may not obligate or expend any funds derived from
collections under 17 U.S.C. 708(d), in excess of the
amount authorized for obligation or expenditure in appro-
priations Acts: Provided further, That not more than
$5,984,000 shall be derived from collections during fiscal
year 2002 under 17 U.S.C. 111(d)(2), 119(b)(2), 802(h),
and 1005: Provided further, That the total amount avail-
able for obligation shall be reduced by the amount by
which collections are less than $27,864,000: Provided fur-
HR 2647 PP
ther, That not more than $100,000 of the amount appro-
priated is available for the maintenance of an ‘‘Inter-
national Copyright Institute’’ in the Copyright Office of
the Library of Congress for the purpose of training nation-
als of developing countries in intellectual property laws
and policies: Provided further, That not more than $4,250
may be expended, on the certification of the Librarian of
Congress, in connection with official representation and
reception expenses for activities of the International Copy-
right Institute and for copyright delegations, visitors, and
seminars.
BOOKS FOR THE BLIND AND PHYSICALLY HANDICAPPED
SALARIES AND EXPENSES
For salaries and expenses to carry out the Act of
March 3, 1931 (chapter 400; 46 Stat. 1487; 2 U.S.C.
135a), $49,788,000, of which $14,437,000 shall remain
available until expended.
FURNITURE AND FURNISHINGS
For necessary expenses for the purchase, installation,
maintenance, and repair of furniture, furnishings, office
and library equipment, $7,932,000.
ADMINISTRATIVE PROVISIONS
SEC. 201. Appropriations in this Act available to the
Library of Congress shall be available, in an amount of
not more than $203,560, of which $60,486 is for the Con-
HR 2647 PP
gressional Research Service, when specifically authorized
by the Librarian of Congress, for attendance at meetings
concerned with the function or activity for which the ap-
propriation is made.
SEC. 202. (a) No part of the funds appropriated in
this Act shall be used by the Library of Congress to ad-
minister any flexible or compressed work schedule which—
(1) applies to any manager or supervisor in a
position the grade or level of which is equal to or
higher than GS–15; and
(2) grants such manager or supervisor the right
to not be at work for all or a portion of a workday
because of time worked by the manager or super-
visor on another workday.
(b) For purposes of this section, the term ‘‘manager
or supervisor’’ means any management official or super-
visor, as such terms are defined in section 7103(a)(10)
and (11) of title 5, United States Code.
SEC. 203. Appropriated funds received by the Library
of Congress from other Federal agencies to cover general
and administrative overhead costs generated by per-
forming reimbursable work for other agencies under the
authority of sections 1535 and 1536 of title 31, United
States Code, shall not be used to employ more than 65
employees and may be expended or obligated—
HR 2647 PP
(1) in the case of a reimbursement, only to such
extent or in such amounts as are provided in appro-
priations Acts; or
(2) in the case of an advance payment, only—
(A) to pay for such general or administra-
tive overhead costs as are attributable to the
work performed for such agency; or
(B) to such extent or in such amounts as
are provided in appropriations Acts, with re-
spect to any purpose not allowable under sub-
paragraph (A).
SEC. 204. Of the amounts appropriated to the Li-
brary of Congress in this Act, not more than $5,000 may
be expended, on the certification of the Librarian of Con-
gress, in connection with official representation and recep-
tion expenses for the incentive awards program.
SEC. 205. Of the amount appropriated to the Library
of Congress in this Act, not more than $12,000 may be
expended, on the certification of the Librarian of Con-
gress, in connection with official representation and recep-
tion expenses for the Overseas Field Offices.
SEC. 206. (a) For fiscal year 2002, the obligational
authority of the Library of Congress for the activities de-
scribed in subsection (b) may not exceed $114,473,000.
HR 2647 PP
(b) The activities referred to in subsection (a) are re-
imbursable and revolving fund activities that are funded
from sources other than appropriations to the Library in
appropriations Acts for the legislative branch.
(c) For fiscal year 2002, the Librarian of Congress
may temporarily transfer funds appropriated in this Act
under the heading ‘‘LIBRARY OF CONGRESS—SALA-
RIES
AND EXPENSES’’ to the revolving fund for the
FEDLINK Program and the Federal Research Program
established under section 103 of the Library of Congress
Fiscal Operations Improvement Act of 2000 (Public Law
106–481; 2 U.S.C. 182c): Provided, That the total amount
of such transfers may not exceed $1,900,000: Provided
further, That the appropriate revolving fund account shall
reimburse the Library for any amounts transferred to it
before the period of availability of the Library appropria-
tion expires.
SEC. 207. Section 101 of the Library of Congress
Fiscal Operations Improvement Act of 2000 (Public Law
106–481; 2 U.S.C. 182a) is amended—
(1) in the heading, by striking ‘‘AUDIO AND
VIDEO’’; and
(2) in subsection (a), by striking ‘‘audio and
video’’.
HR 2647 PP
ARCHITECT OF THE CAPITOL
LIBRARY BUILDINGS AND GROUNDS
STRUCTURAL AND MECHANICAL CARE
For all necessary expenses for the mechanical and
structural maintenance, care and operation of the Library
buildings and grounds, $22,252,000, of which $8,918,000
shall remain available until expended.
GOVERNMENT PRINTING OFFICE
OFFICE OF SUPERINTENDENT OF DOCUMENTS
SALARIES AND EXPENSES
(INCLUDING TRANSFER OF FUNDS)
For expenses of the Office of Superintendent of Doc-
uments necessary to provide for the cataloging and index-
ing of Government publications and their distribution to
the public, Members of Congress, other Government agen-
cies, and designated depository and international exchange
libraries as authorized by law, $29,639,000: Provided,
That travel expenses, including travel expenses of the De-
pository Library Council to the Public Printer, shall not
exceed $175,000: Provided further, That amounts of not
more than $2,000,000 from current year appropriations
are authorized for producing and disseminating Congres-
sional serial sets and other related publications for 2000
and 2001 to depository and other designated libraries:
Provided further, That any unobligated or unexpended bal-
HR 2647 PP
ances in this account or accounts for similar purposes for
preceding fiscal years may be transferred to the Govern-
ment Printing Office revolving fund for carrying out the
purposes of this heading, subject to the approval of the
Committees on Appropriations of the House of Represent-
atives and Senate.
GOVERNMENT PRINTING OFFICE REVOLVING FUND
The Government Printing Office is hereby authorized
to make such expenditures, within the limits of funds
available and in accord with the law, and to make such
contracts and commitments without regard to fiscal year
limitations as provided by section 9104 of title 31, United
States Code, as may be necessary in carrying out the pro-
grams and purposes set forth in the budget for the current
fiscal year for the Government Printing Office revolving
fund: Provided, That not more than $2,500 may be ex-
pended on the certification of the Public Printer in connec-
tion with official representation and reception expenses:
Provided further, That the revolving fund shall be available
for the hire or purchase of not more than 12 passenger
motor vehicles: Provided further, That expenditures in con-
nection with travel expenses of the advisory councils to
the Public Printer shall be deemed necessary to carry out
the provisions of title 44, United States Code: Provided
further, That the revolving fund shall be available for tem-
HR 2647 PP
is to remain available until expended for the acquisition
and partial support for implementation of an Integrated
Library System (ILS): Provided further, That of the
amount appropriated, $500,000 shall remain available
until expended for the Abraham Lincoln Bicentennial Com-
mission, of which amount $3,000 may be used for official
representation and reception expenses of the Abraham Lin-
coln Bicentennial Commission.
COPYRIGHT OFFICE
SALARIES AND EXPENSES
For necessary expenses of the Copyright Office,
$40,701,000, of which not more than $21,880,000, to re-
main available until expended, shall be derived from collec-
tions credited to this appropriation during fiscal year 2002
under 17 U.S.C. 708(d): Provided, That the Copyright Of-
fice may not obligate or expend any funds derived from col-
lections under 17 U.S.C. 708(d), in excess of the amount
authorized for obligation or expenditure in appropriations
Acts: Provided further, That not more than $5,984,000 shall
be derived from collections during fiscal year 2002 under
17 U.S.C. 111(d)(2), 119(b)(2), 802(h), and 1005: Provided
further, That the total amount available for obligation shall
be reduced by the amount by which collections are less than
$27,864,000: Provided further, That not more than
$100,000 of the amount appropriated is available for the