*District Judge of the Southern District of Texas, sitting by designation. 

United States Court of Appeals,

Fifth Circuit.

No. 91-3837.

ENPLANAR, INC., V. Keeler & Company, Inc. and Dragon Limited, Inc., Plaintiffs-Appellants,

v.

John MARSH, In His Official Capacity as Secretary of the Army of the United States, et al.,

Defendants-Appellees.

Jan. 19, 1994.

Appeal from the United States District Court for the Eastern District of Louisiana.

Before REYNALDO G. GARZA and GARWOOD, Circuit Judges and WERLEIN,* District Judge.

GARWOOD, Circuit Judge:

This case involvesthe grant ofsummaryjudgment against a suit for unspecified damagesfrom

a three-month suspension of a discretionary minority set-aside program. E.J.A., Inc. (EJA);

Enplanar, Inc. (Enplanar); Dragon Limited, Inc. (Dragon); and V. Keeler & Co., Inc. (Keeler)

appeal the district court's grant of summary judgment in favor of the United States Army Corps of

Engineers (the Corps). We affirm.

Facts and Proceedings Below

This case relatesto the Corps' administration of itsset-aside program for minority businesses

(the 8(a) program), as described in the SmallBusiness Act § 8(a), 15 U.S.C. § 637(a). The operation

of the 8(a) program is delineated in Fordice Constr. Co. v. Marsh, 773 F.Supp. 867, 869-70

(S.D.Miss.1990). As noted in that opinion, Congress created the 8(a) program to encourage minority

small-business enterprises. Id. at 869. Under this program, the Small Business Administration (SBA)

determines which minority businesses are eligible to participate in the 8(a) program. 15 U.S.C. §

637(a)(4)-(8). The SBA then acts as an intermediary between government procurement

agencies—such as the Corps—and these certified minority businesses. Under this system, a

procurement agency's proposed project may be placed in the 8(a) program in one of three ways, all
 

1A minority contractor may also influence this discretionary process through informal

"self-marketing." Self-marketing is a way for 8(a) contractors to notify a procurement agency of

projects the agency could choose to refer to the SBA. The 8(a) contractors contact that agency's

personnel and market their services concerning projects that the contractors could work on. The

agency can then decide to refer the project to the SBA which may, in its discretion, give the

project to the contractor who engaged in the self-marketing. 48 C.F.R. §§ 19.803(c), 19.804-

2(a)(12). 

of which are entirely at the discretion of the SBA and the procurement agency: (1) the SBA advises

the procurement agency of an 8(a) firm's capabilities and asks that agency to identify and submit to

the 8(a) program its proposed contracts that support the firm's business plan; (2) the SBA identifies

a specific contract for a particular 8(a) firm and asks the agency to offer the contract to the 8(a)

programfor the firm; or (3) the agency reviews its proposed contracts and identifies and offers those

which are suitable for the 8(a) program. Id. at 637(a)(1)(A); 48 C.F.R. §§ 19.800(b), 19.803(a)-(c),

19.804.1 Once a contract has been set aside for minority businesses, the SBA then selects the

minority contractor best suited to perform the contract. 15 U.S.C. § 637(a)(1)(B), (a)(7)(A); 13

C.F.R. § 124.307(d). The SBA, on behalf of the minority contractor, then certifies to the

procurement agency that the minority contractor can perform the contract, and the SBA begins to

negotiate with the agency's contracting officer upon mutually agreeable terms and conditions. 48

C.F.R. § 19.800(c). Alternatively, upon mutual agreement between the SBA and the agency, the

minority contractor itself may be allowed to negotiate with the agency. 48 C.F.R. § 19.808-1(b).

Throughout this process, it is within the procurement agency's discretion to withdraw the project

from the 8(a) program before the contract is awarded. 48 C.F.R. § 19.800(c). Finally, the minority

contractor cannot be awarded the project if the price of the contract results in a cost to the

procurement agency which exceeds a fair market price. 48 C.F.R. § 19.806(b).

Prior to the case sub judice, three nonminority small-business contractors challenged the

Corps' joint administration of the 8(a) program with the SBA. Specifically, these contractors

challenged the Corps' submission practice whereby it set aside one-hundred percent of its

small-business contracts for minority businesses. These contractors contended that in setting aside

one-hundred percent of the contracts, the agencies failed to consider the effect a minority enterprise

set-aside would have on competing nonminority small-business contractors. The district court
 

2Subsequently, this advice was at least partially confirmed by this Circuit, which held in a

separate case that the Corps there properly administered the 8(a) program in conformity with

newly promulgated regulations. See 48 C.F.R. 19.804-1(2)(3); Valley Constr. Co. v. Marsh, 984

F.2d 133, 135 (5th Cir.1993) (Valley II ) (Corps reasonably interpreted regulation not to require

"impact analysis" for "new, non-recurring construction contracts"). The appellant attempted to

rely on Fordice as authority for the proposition that the Corps was still improperly awarding

contracts to minority businesses under the 8(a) program because it was not considering the

economic impact of nonminority businesses, but we determined that "[n]ot only is Fordice

factually distinguishable from this case, but it is non-binding on this court." Id. at 135 n. 5. 

initially dismissed the suit on mootness grounds, and we reversed. Valley Constr. Co. v. Marsh, 714

F.2d 26 (5th Cir.1983) (Valley I ). On remand, the district court held that the Corps' administration

of the 8(a) program impermissibly excluded the nonminority small-business contractors in violation

of 42 U.S.C. § 2000d, and that the SBA ignored its statutorily directed policy pursuant to 15 U.S.C.

§ 637(d)(1) requiring it to consider the economic impact on these contractors. Fordice, 773 F.Supp.

at 882. The government initially appealed the decision, but it withdrew its appeal on October 23,

1990.

In early November 1990, in response to the Fordice decision and the withdrawal of the

government's appeal, the Corps sought legal guidance from Army Headquarters concerning the

continuing legality of its administration of the 8(a) program, and the possible personal liability of the

contracting officers in submitting contracts to the SBA under the program. While awaiting advice,

the Corps continued to abide by previously awarded 8(a) contracts, and exercised the options on all

8(a) contracts for extending performance by the minority contractor into later years. Although the

Corps did not terminate any pre-existing 8(a) contracts, it did hold in abeyance any ongoing activity

in reference to 8(a) contracts not yet awarded. This abeyance continued until January 22, 1991, when

the Corps received guidance from Army Headquarters notifying it that, as to the currently

administered 8(a) program, there existed no legal impediment to awarding contracts to the SBA

through the 8(a) program.2

On January 8, 1991, EJA, Enplanar, Dragon, and Keeler (collectively, the Contractors)

brought suit in Louisiana seeking injunctive and declaratory relief against, inter alia, the Corps and

its personnel in their official capacities, and the SBA (collectively, the Defendants), claiming that the

Corps'suspension oftheir 8(a) referralsto the SBA discriminated against the Contractorsin violation
 

3Keeler began negotiating for the Cotton Meade project on April 25, 1989. The Corps

withdrew the project from the 8(a) program on August 28, 1990. Keeler claimed that this project

was withdrawn in bad faith. 

of 42 U.S.C. §§ 1981, 1985(3), 2000d. The Contractors also argued that the suspension was an

unconstitutional taking of their property rights without due process.

Specifically, EJA alleged that, prior to the abeyance, the Corpsfailed to renew the Southwest

Pass program even though EJA had worked on the project during the previous year. The Corps did

not dispute that in April of 1990, it had decided not to place the project in the 8(a) program because

it already had four of its ten small-business projects in the program, and was concerned about the

potential legal liability of adding more small-business projectsto the 8(a) program. EJA alleged that

it had a reasonable expectancy that the project would be renewed but because of the constitutional

concerns, the project was pulled from the 8(a) program. Enplanar alleged that it was in negotiations

concerning two 8(a) contracts but the Corps' suspension had indefinitely postponed the

implementation of these projects. Dragon and Keeler alleged that the suspension had indefinitely

delayed the Corpsfrom making referralsfor other, unspecified, future projects which the SBA might

give to Dragon or Keeler when and if the projects materialized. Finally, Keeler also alleged that the

Corps had wrongfully failed to award it the Cotton Meade project.3 The Contractors asked for

injunctive relief which would remove the suspension and order the Corps to award the Southwest

Pass project to EJA and the Cotton Meade Project to Keeler.

On February8, the district court directed the partiesto brief whether the SBAwas a necessary

party in light of the fact that the suspension had been lifted. On February 27, in its responsive brief,

the Contractors stated that the SBA was not a necessary party, and indicated in the summary of its

argument that all injunctive relief was moot. However, in the argument itself, they asked for

injunctive relief as to the Cotton Meade project. On March 13, the district court denied the

Contractors' partial motion for summary judgment seeking injunctive relieffinding that allsuch relief

was moot.

The Defendants then filed motions for summary judgment and for change of venue. On

March 26, the magistrate stayed discovery pending a ruling on the venue motion. The Contractors
 

4This response also included a supplemental memorandum concerning the Defendants' earlier

motion to dismiss the complaint against Green and Page. The Defendants argued that their

service had been improper under Federal Rule of Civil Procedure 4(c)(2)(C)(ii) and that therefore

their complaint should be dismissed pursuant to Rule 12(b)(5). 

made a Rule 56(f) motion to compel discovery, which was denied. Subsequently, the Contractors

filed an amended complaint alleging post-suspension claims for retaliation and unconstitutional

interference with the Contractors'rights of accessto the courts, based on the Corps engineers'refusal

to meet with the Contractors during the pendency of this suit. This amended complaint added as

defendantsCorps' engineers StephensonW. Page (Page) andRobert Green(Green) in theirindividual

capacities (the original complaint had included them in their official capacities). It also requested

attorneys' fees, claiming that the Contractors' lawsuit caused the Corps to lift its suspension. In

response, the Defendantsfiled a supplemental memorandum in support of their motionsforsummary

judgment, addressing the new claims.4 On July 15, the district court granted summary judgment on

all of the Contractors' claims except for Keeler's claims concerning the Cotton Meade project. These

latter claims were transferred to Mississippi based on the Defendants' motion for change of venue.

Discussion

The Contractors now argue on appeal that the district court erred by: (1) denying their

motion for partialsummary judgment on the merits for injunctive relief; (2) denying their additional

discovery; (3) prematurely ruling on their claims; (4) granting summary judgment against their

claims concerning the Defendants' alleged suspension of the 8(a) program and retaliation; (5)

dismissing their claim for attorneys fees; and (6) granting the change of venue motion regarding

Keeler's Cotton Meade project claims.

I. Denial of Injunctive Relief

The Contractors cont end that the district court erred in denying as moot their motion for

partial summary judgment concerning injunctive relief. They admit that the resumption of the 8(a)

program did moot their request for injunctive and declaratory relief which sought to lift the Corps'

suspension of the 8(a) program. However, they argue that the district court erred in ruling that they

also were not entitled to injunctive relief concerning the Southwest Pass project and the Cotton
 

5The Contractors argue that the SBA is no longer a party in this case except for its possible

liability as to attorneys' fees, and that any injunctive relief granted concerning the Southwest Pass

and Cotton Meade projects would not affect the SBA. We disagree. If a court ordered the Corps

to award these projects to specific 8(a) participants, this order would also require injunctive relief

concerning the SBA's conduct as to its statutory duties regarding its selection of 8(a) contractors

for a specific project, and its subsequent negotiations with a procurement agency concerning the

terms of the project's contract. See 13 C.F.R. §§ 124.307(d), 124.308(d), 124.309; 48 C.F.R. §

19.800(c). 

 

6The Contractors argue that this holding is no longer binding because The Federal Courts

Improvement Act of 1982 as codified at 28 U.S.C. § 1491(a)(3) now allows injunctive relief

against the SBA—and by extension, against agencies participating in the SBA's programs. This

Court has not addressed the effect that section 1491(a)(3) has on the injunctive immunity of the

SBA, although other courts have recognized that this law abrogates the SBA's injunctive

immunity in certain circumstances. See Cavalier Clothes, Inc. v. United States, 810 F.2d 1108,

1111-112 (Fed.Cir.1987); Related Industries, Inc. v. United States, 2 Cl.Ct. 517 (1983). 

However, we need not decide this issue because section 1491(a)(3) applies only to cases brought

before the United States Court of Federal Claims. 28 U.S.C. § 1491(a)(1); Cavalier, 810 F.2d at

1112 (holding that this section "specifically empowers the Claims Court generally to grant

injunctive relief" against the SBA). Since this case was not brought before the Claims Court,

section 1491(a)(3) is irrelevant.

The Contractors also argue that other circuits have held that the SBA is subject to

injunctive relief in certain circumstances regardless of the applicability of section

1491(a)(3). See Ulstein Maritime, Ltd. v. United States, 833 F.2d 1052, 1056 (1st

Meade project. They contend that the district court erroneously found all of their requested

injunctive reliefmoot based on theirstatement summarizing the argument in their briefthat the Corps'

resumption of awarding new 8(a) contracts "moots allinjunctive relief concerning the 8(a) Program."

They now contend that the argument in their briefmade clear that only the injunctive reliefrequesting

the suspension's removal was moot and that the relief regarding the specific projects was not moot.

We tend to agree. A party should not fear the forfeit of his requested relief based merely on a

statement made in the introductory section of his briefsummarizing his argument. However we still

find that the district court did not err in denying such relief.

In Valley I, we held that asto the Corps' administration ofthe 8(a) program, "injunctive relief

would be improper because a necessary party to the suit is the SBA, which administers the overall

§ 8(a) minority enterprise set-aside program. The Small Business Act, 15 U.S.C. § 634(b)(1),

precludes injunctive relief against the SBA. We ... will not allow the contractors to obtain indirectly

(against the Army) what they cannot obtain directly (against the SBA)." 714 F.2d at 29.5 We find

that this holding is the controlling law in this case.6 The district court did not err in finding that the
Cir.1987), and cases cited therein. However, as noted by Ulstein, this Circuit has

"concluded that all injunctive relief directed at the SBA is absolutely prohibited." Id. We

are bound by our prior decisions that such relief is barred. See Valley I, 714 F.2d at 29,

Romeo v. United States, 462 F.2d 1036, 1038 (5th Cir.1972), cert. denied, 410 U.S. 928,

93 S.Ct. 1361, 35 L.Ed.2d 589 (1973); Expedient Servs., Inc. v. Weaver, 614 F.2d 56

(5th Cir.1980). 

 

7Furthermore, as to EJA's claims concerning the Southwest Pass project, during oral argument

it was revealed that EJA no longer exists, and therefore it cannot perform the contract. 

Consequently, the injunctive relief sought is actually "equitable monetary" relief which would

provide money damages in lieu of the injunctive relief. Federal courts have granted injunctive

relief against governmental units in which the performance of such relief would cost money. See

Edelman v. Jordan, 415 U.S. 651, 680, 94 S.Ct. 1347, 1364, 39 L.Ed.2d 662 (1974) (Douglas,

J., dissenting) (noting that in cases involving injunctive relief against state government entities

"[m]ost ... decisions by federal courts have a financial impact on the States"). Furthermore, "a

court in equity may award monetary restitution as an adjunct to injunctive relief." Tull v. United

States, 481 U.S. 412, 424, 107 S.Ct. 1831, 1839, 95 L.Ed.2d 365 (1987). However, the

Contractors do not cite to any authority where a court has granted monetary damages to a party

as a substitute for injunctive relief. To allow such a result would destroy the distinction between

monetary and equitable damages. See Edelman, 415 U.S. at 666, 94 S.Ct. at 1357 (rejecting the

contention that in an equity proceeding relief in the form of money damages may be awarded

under the rubric of "equitable restitution" because "the relief may be labeled "equitable' in

nature"). Furthermore, since EJA's claim concerning the Southwest Pass project names only the

Corps and its divisions as defendants, it is thereby suing only the United States. Consequently, it

should have brought such a monetary claim in the Court of Claims. See Amoco Production Co. v.

Hodel, 815 F.2d 352, 359 (5th Cir.1987), cert. denied, 487 U.S. 1234, 108 S.Ct. 2898, 101

L.Ed.2d 932 (1988). We conclude that the district court did not err in denying injunctive relief as

to EJA's claims concerning the Southwest Pass project.

As to the Cotton Meade project, the district court's ruling is not before us. 

Keeler's claims concerning this project have not been disposed of, but merely transferred

to a different venue. Therefore, the district court's ruling denying the Contractors' partial

summary-judgment motion concerning the availability of injunctive relief as to this project

is an interlocutory order not subject to appeal at this time. See 10 Charles A. Wright &

Arthur R. Miller, FEDERAL PRACTICE AND PROCEDURE § 2715 p. 636 (noting that "the

denial of a Rule 56 motion is an interlocutory order from which no appeal is available until

the entry of judgment"); see also In re Corrugated Container Antitrust Litigation, 694

F.2d 1041 (5th Cir.1983). 

Contractors were barred from receiving injunctive relief against the Corps concerning its

administration of the 8(a) program.7

II. Discovery

The Contractors claim that the district court denied them proper discovery so that they were

unable to create contested issues of fact to overcome the Defendants' summary judgment motions.

Specifically, the Contractors contend that they were improperly denied discovery as to the abeyance

of the 8(a) program, and as to Keeler's Cotton Meade claims. In reviewing such claims, "The trial
judge's decision to curtail discovery is granted great deference and, thus, is reviewed under an abuse

of discretion standard." Wichita Falls Office Assoc. v. Banc One Corp., 978 F.2d 915, 918 (5th

Cir.1992), cert. denied, --- U.S. ----, 113 S.Ct. 2340, 124 L.Ed.2d 251 (1993); see also Landry v.

Air Line Pilots Ass'n Int'l, 901 F.2d 404, 436 (5th Cir.), cert. denied, 498 U.S. 895, 111 S.Ct. 244,

112 L.Ed.2d 203 (1990).

As to the Cotton Meade project, these claims were not disposed of in summary judgment,

but were rather transferred to another court based on the Defendants' motion for change of venue.

28 U.S.C. § 1404(a); FED.R.CIV.P. 21. As such, the claims were still alive and still subject to

discovery—albeit in a different venue. The Contractors cite to no authority, and we have found none,

holding the district court has abused its discretion in denying merits-related discovery pending ruling

on a motion for change of venue. Federal courts have long recognized that two of the factors

supporting a change in venue are convenience of the witnesses and the location of records and

documents. 15 Charles A. Wright & Arthur R. Miller, FEDERALPRACTICEANDPROCEDURE §§ 3851,

3853; see also Southern Investors II v. Commuter Aircraft Corp., 520 F.Supp. 212, 218

(M.D.La.1981); American Standard, Inc. v. Bendix Corp., 487 F.Supp. 254, 264 (W.D.Mo.1980).

Although these factors are usually considered in connection with securing the witnesses' and

documents' availability for trial, they also necessarily implicate the ease of conducting merits-related

discovery in a location which is near the relevant witnesses and documents. Moreover, if a change

of venue motion is granted, the discoveryis not denied but merelydelayed. The Contractors tendered

no showing that the delay in discovery somehow prejudiced their case respecting the Cotton Meade

project through loss of documents or unavailability of witnesses. See FED.R.CIV.P. 61; FDIC v.

Fuller, 994 F.2d 223 (5th Cir.1993); King v. Gulf Oil Co., 581 F.2d 1184 (5th Cir.1978). The

district court did not abuse its discretion in refusing to allow discovery concerning Keeler's claims

arising from the Cotton Meade project pending the grant of the Defendants' change of venue motion

regarding these claims.

Concerning the remaining claims, which were subsequently disposed of by the district court's

grant of the Defendants' summary judgment motion, the Contractors were entitled to receive a
 

8The Contractors now complain on appeal that they were denied needed discovery as to: (1)

an October 17, 1990 memorandum prepared by a member of the Corps; (2) a November 15,

1990 memorandum prepared by the Corps' assistant general counsel; (3) an undated

memorandum by the Vicksburg district counsel; and (4) the September 1990 written

recommendations of the Department of Justice, Small Business Administration, and the

Department of the Army concerning the constitutionality of the 8(a) program. None of these

matters were the subject of the Contractors' Rule 56(f) motions or equivalents. In their reply

brief, the Contractors assert, with no citation to the record, that they notified the district court of

their need for these documents. After a fruitless search of the record, we conclude that there

continuance for additional discovery if they: (i) requested extended discovery prior to the court's

ruling on summary judgment; (ii) placed the district court on notice that further discovery pertaining

to the summary judgment motion was being sought; and (iii) demonstrated to the district court with

reasonable specificityhowthe requested discoverypertained to the pending motion. Chevron U.S.A.,

Inc. v. Traillour Oil Co., 987 F.2d 1138, 1155-56 (5th Cir.1993); Wichita Falls, 978 F.2d at 919

(citing Int'l Shortstop, Inc. v. Rally's, Inc., 939 F.2d 1257 (5th Cir.1991)).

Asto the first two requirements, we can review a claimalleging improperly denied discovery

only if the complaining party presented to the district court a Rule 56(f) motion or an " "equivalent

statement preferably in writing' that conveys the need for additional discovery" in the areas now

complained of on appeal. Wichita Falls, 978 F.2d at 919 (quoting Fontenot v. Upjohn Co., 780 F.2d

1190, 1194 (5thCir.1986)). In this regard, the Contractors contend in their reply brief that they made

a Rule 56(f) motion or its equivalent in six separate instances. However, as to four of the motions

cited to us, even when read broadly as complying with the requirements of Rule 56(f), these motions

concern only the Cotton Meade project. Therefore, as to these motions, the Contractors failed to

inform the district court that they were seeking any additional discovery outside the scope of that

project.

Only in two motions, do the Contractors bring to the district court's attention a request for

additional discovery concerning claims other than the Cotton Meade project. In their opposition

motion and additional opposition motion to the Defendants' motions for summary judgment and for

change of venue, the Contractors note in passing that they have been refused a copy of the Justice

Department's memorandum concerning its October 1990 determination not to appeal the Fordice

decision.8 In these passing references, they do not explain how this requested discovery would or
exists no indication in the record that these matters were brought to the attention of the district

court, and therefore, it did not abuse its discretion in refusing to allow discovery concerning these

matters. 

 

9We infer from the placement of the stray remark noting that the Contractors had been denied

this memorandum, that this undiscovered document will bolster their argument that the 8(a)

program was suspended based on the Corps' contracting officers fear of personal liability. 

However, this matter is undisputed. 

could create a fact issue to overcome the Defendants' summary-judgment motion.9 Therefore, they

have failed the third requirement which requires them to demonstrate to the district court with

reasonable specificity how the requested discovery would likely pertain to the pending summary

judgment motion. See Krim v. BancTexas Group, Inc., 989 F.2d 1435, 1442 (5thCir.1993) (holding

that a nonmovant's Rule 56(f) motion was insufficient where "absent from the affidavit was an

explanation of ... how the materials listed in the plaintiff's first document request, or in the

handwritten list appended to the affidavit, would enable plaintiff to oppose defendant's summary

judgment motion by establishing a genuine issue of material fact"). Certainly, we are not requiring

clairvoyance on the part of the Contractors. They do not need to know the precise content of the

requested discovery, but they do need to give the district court some idea of how the sought-after

discovery might reasonably be supposed to create a factual dispute. The mere fleeting mention of a

matter, without a description of its likely relevance, will not suffice to alert the district court to the

potential import ance of t hat undiscovered item. Therefore, the district court did not abuse its

discretion in denying additional discovery.

III. Summary Judgment Procedure

The Contractors complain that the district court prematurely dismissed their claims of

retaliation against defendants Page and Green in their individual capacity, and that it prematurely

granted summary judgment in favor of all of the Defendants without giving the Contractors notice.

Specifically, the Contractors assert that the district court sua sponte dismissed their claims against

Page and Green because the only motion filed on their behalf was a motion to dismiss for improper

service which was subsequently cured. Furthermore, the Contractors claim that the district court

granted summary judgment dismissing their amended complaint although the Defendants failed to
 

10This case is distinguishable from Reese v. Sparks, 760 F.2d 64 (3d Cir.1985), which held that

a district court could not grant summary judgment on an amended complaint based on a motion

for summary judgment filed before that amended complaint if the amended complaint contained

new legal theories and additional, different facts. Id. at 66. Here, the equivalent of a summary

judgment motion was properly filed after the amended complaint and it specifically addressed the

new claims alleged in it. 

move for summary judgment as to that complaint.

These two arguments conveniently overlook the Defendants' supplemental memorandum in

support of their motionsforsummary judgment. This document was filed on May 13, 1991, after the

Contractors' amended complaint, and it specifically addresses the claims in that amended complaint.

This document addresses, as a ground for dismissal, the Contractors' failure to properly serve Page

and Green, but it also explicitly discusses various grounds for summary judgment as to all the

defendants—including the retaliation claims brought against Page and Green. Therefore, this

memorandum served to supplement the original summary judgment motion, and provided the

Contractors with notice of the Defendants' challenges to their amended complaint. Cf. Spickard v.

Ribicoff, 211 F.Supp. 555, 558 (W.D.Ky.1962) (granting summary judgment where no motion was

filed but the movant submitted a brief in support of summary judgment and the nonmovant treated

it as a summary judgment motion).10 Although the district court on July 15, 1991, granted a dismissal

as to Page and Green, it also granted summary judgment as to all the defendants based on evidence

not contained in the pleadings. Under these circumstances, the district court's order to dismiss the

complaint asto Page and Green is disregarded, and we instead review the grant ofsummary judgment

as to all defendants—including Page and Green. See FED.R.CIV.P. 12(b); Wilson v. U.S. Dept. of

Agriculture, 991 F.2d 1211, 1214 (5th Cir.1993); Conoco, Inc. v. Republic Ins. Co., 819 F.2d 120,

122 n. 1 (5th Cir.1987) (treating a court's order as granting summary judgment and disregarding the

statement in the order directing, "and this case is dismissed"). The district court did not sua sponte

dismissthe claims against Page and Green, but rather granted summary judgment in their favor based

on the Defendants' memorandum in support of summary-judgment filed approximately two months

previously. Cf. Carolinas Cotton Growers Ass'n v. United States, 785 F.2d 1195, 1200 (4th

Cir.1986) ("[I]t is the conclusion of the court that the references to summary judgment are in fact
 

11Since the Defendants filed the supplement to their summary-judgment motion some two

months before the district court entered summary judgment, the Contractors received sufficient

notice of the Defendants' new arguments supporting their summary judgment motion. See

FED.R.CIV.P. 56(c) (requiring that the summary judgment motion "shall be served at least 10 days

before the time fixed for the hearing"); Arkwright-Boston Mfrs. Mut. Ins. Co. v. Aries Marine

Corp., 932 F.2d 442, 445 (5th Cir.1991); Atchison, T. & S. F. R. Co. v. Buell, 480 U.S. 557, 568

n. 15, 107 S.Ct. 1410, 1417 n. 15, 94 L.Ed.2d 563 (1987). This two-month notice also satisfied

the "hearing" requirement in Rule 56(c). As long as the nonmovants have sufficient notice of the

pending summary judgment motion, the district court may rule on that motion based solely on the

pleadings and evidence on file without a formal conference with the parties. See Western Fire

Ins. Co. v. Copeland, 786 F.2d 649, 652 (5th Cir.1986) (holding that the district court erred by

not affording the nonmovants "either the ten-day notice of Rule 56(c) or an opportunity to

present their evidence"); Cowgill v. Raymark Indus. Inc., 780 F.2d 324, 329 (3d Cir.1985)

(holding that nonmovant not entitled to notice of date when motion for summary judgment would

be resolved because the nonmovant "is under an obligation to respond ... in a timely fashion and

to place before the court all materials it wishes to have considered when the court rules on the

motion"); see also Daniels v. Morris, 746 F.2d 271 (5th Cir.1984); Brumley Estate v. Iowa Beef

Processors, Inc., 704 F.2d 1351 (5th Cir.1983), cert. denied, 465 U.S. 1028, 104 S.Ct. 1288, 79

L.Ed.2d 690 (1984). 

simply mislabelings not affecting the validity of the finding of the court below.").11 This equivalent

of a motion for summary judgment explicitly also covered the other defendants, and served as the

proper basisfor the district court'ssummary judgment asto those defendants. Therefore, the district

court did not prematurely rule on the Contractors' claims.

IV. Summary Judgment Claims

The Contractors contend that the district court erred in granting summary judgment

dismissing the claims in their amended complaint. This Court reviews a district court's grant of

summary judgment de novo, taking the evidence and inferences to be drawn therefrom in the light

most favorable to the nonmoving party, and determining whether the pleadings, depositions, answers

to interrogatories, and affidavits show that there is no genuine issue of material fact and that the

moving party is entitled to judgment as a matter of law. Crenshaw v. General Dynamics Corp., 940

F.2d 125, 127 (5th Cir.1991); FED.R.CIV.P. 56(c). Summary judgment is proper "against a party

who failsto make a showing sufficient to establish the existence of an element essential to that party's

case, and on which that party will bear the burden of proof at trial." Celotex Corp. v. Catrett, 477

U.S. 317, 322, 106 S.Ct. 2548, 2552, 91 L.Ed.2d 265 (1986). Here, the burden of proof was on the

Contractors.

The Contractors first argue that the district court erred in ruling that they were not entitled
 

12The Contractors also claim on appeal that they were denied a property interest without

procedural due process in violation of the due process clause of the Fifth Amendment because the

suspension was enacted without notice or a hearing. As a result, they claim they are entitled to

monetary damages on a Bivens constitutional-tort claim based on the suspension. See Bivens v.

Six Unknown Agents of Federal Bureau of Narcotics, 403 U.S. 388, 91 S.Ct. 1999, 29 L.Ed.2d

619 (1971). However, a Bivens claim is available only against government officers in their

individual capacities. Williamson v. U.S. Dept. of Agriculture, 815 F.2d 368, 380 (5th Cir.1987)

(holding that a Bivens claim "only applies against the individual appellees in their individual

capacities"). In their claim concerning the suspension, the Contractors state that the only

defendants are "the Corps of Engineers and the Vicksburg Corps," which are subdivisions of the

United States. The United States may be sued only under the Federal Torts Claims Act. See

Rykers v. Alford, 832 F.2d 895, 897 (5th Cir.1987) (holding that "[t]he United States may be

sued only within the exception to sovereign immunity provided by the Federal Torts Claims Act"). 

This the Contractors have failed to do. The Contractors have not raised a cognizable Bivens

claim concerning the suspension. 

to declaratory relief arising from the partial suspension of the 8(a) program.12 They contend that

because of their minority status they were denied their equal-protection rights, and that the 8(a)

program was administered in a discriminatory manner in violation of 42 U.S.C. §§ 1981, 1985(2),

2000d. However, the Defendants articulated a nondiscriminatory reason for the suspension, namely

that it was due to the Fordice decision which found that the Corps' practice of awarding a large

number ofsmall-business projectsto the minority set-aside programwasimproper. The Contractors

admit in their briefs to this Court that the suspension was due to the Defendants' belief that the 8(a)

program was unconstitutional as a result of the Fordice decision. The Contractors even surmise that

the presidential administration—at the time of the suspension—believed that all minority set-aside

programs were unconstitutional. They then make the conclusory assertion that such a belief was an

unjustified pretext. We disagree.

The three-month suspension affected only the Corps' decisions regarding the submission of

new projects to the SBA. Such a decision is within the complete discretion of the Corps. 48 C.F.R.

§ 19.803(a)-(c). Even when the Corps offers a project to the SBA, it is then within the SBA's

complete discretion to accept the project, and then to select a minority contractor to work on the

project. 15 U.S.C. § 637(a)(1)(B); 13 C.F.R. §§ 124.307(d), 124.309. Therefore, this is not an

instance where a government agency is accused of discrimination because of its failure to undertake

some mandatory requirement; rather, this is an instance where the agency's discretionary failure can
 

13We do not hold that a minority plaintiff cannot prevail on a claim for discrimination where an

agency has unfettered discretion but chooses to use such discretion to discriminate against

minorities. Rather, we are merely pointing out that complete discretion makes it more difficult for

a minority plaintiff to make out a prima facie case, since the violation of a mandated policy in and

of itself can serve as the basis for the finding of discriminatory intent. See Young v. Pierce, 822

F.2d 1368, 1371 (5th Cir.1987) (finding of discriminatory intent by the Department of Housing

and Urban Development based on its failure to perform its affirmative duty under Title VIII to

learn of and to abate segregation in public housing). 

be fairly attributed to reasons other than invidious discrimination.13 Here, the Corps' decision to

suspend the submission of new contracts to the SBA was reasonable in light of the Fordice decision

in which the district court issued a declaratory judgment finding that the Corps had illegally

administered the 8(a) program—specifically in regard to itssubmission practice. 773 F.Supp. at 882.

If the Fordice decision was a mere pretext for discrimination on the Corps' part, then it seems

remarkable that the Corps would have sought legal advice, and then after a mere three months, the

Corps upon receipt of that advice would have immediately lifted the suspension concerning that part

of the 8(a) program which was directly involved in the Fordice litigation. The Contractors have

failed to carrytheir burden to produce summaryjudgment evidence whichwould sustain a finding that

the Defendants' proffered reasons were a mere pretext for discrimination. See Guthrie v. Tifco

Industries, 941 F.2d 374, 378 (5thCir.1991), cert. denied, --- U.S. ----, 112 S.Ct. 1267, 117 L.Ed.2d

495 (1992) (holding that in deciding a summary judgment motion "[a]bsent countervailing evidence,

the trier of fact must accept the defendant's explanation as the real reason" for the action); Brown

v. American Honda Motor Co., 939 F.2d 946 (11th Cir.1991), cert. denied, --- U.S. ----, 112 S.Ct.

935, 117 L.Ed.2d 106 (1992) (granting summary judgment when "the defendant's proffer of credible,

nondiscriminatoryreasonsfor its actionsissufficientlyprobative, thenthe plaintiffmust come forward

with specific evidence demonstrating that the reasons given by defendant were a pretext for

discrimination"). Given the Corps' unfettered discretion and its real apprehensions regarding the

legality of its administration of the 8(a) program, we find that the Contractors have failed to carry

their burden of proof to refute the reasons offered by the Defendants. See Grigsby v. Reynolds

Metals Co., 821 F.2d 590, 596 (11th Cir.1987) (holding that a defendant can present such strong

evidence of a nondiscriminatory rationale that summary judgment is warranted). Therefore, the
 

14The Contractors also complain that the district court erred in granting summary judgment

against EJA's claim concerning the Southwest Pass project. However, as explained above, the

Corps had complete discretion concerning whether it would submit the project to the 8(a)

program. The Contractors argue that EJA had already worked on the project the prior year and

had an "expectation" that it would receive the project again. They allege it did not receive the

project because the Corps feared that too many of its small business set-asides were going into the

8(a) program. Assuming this explanation is true, it still does not suffice to sustain a finding that

the Corps' decision not to submit the project was based on a discriminatory intent. 

 

15The Contractors also brought this claim against the Corps, but as already explained above,

such a claim is cognizable only against individuals. Williamson, supra. 

district court did not err in granting summary judgment against the Contractors' discrimination

claims.14

Finally, the Contractors contend that the district court erred in rejecting their Bivens claims

for declaratory, injunctive, and monetary relief. Their Bivens claims alleged constitutional torts

against Page and Green for denying the Contractors the ability to self-market their services to the

Corps.15 Under Bivens, "the victim of a constitutional violation by a federal agent has a right to

recover damages against the agent in federal court." Bush v. Lucas, 647 F.2d 573, 575 (5thCir. Unit

B June 1981), aff'd, 462 U.S. 367, 103 S.Ct. 2404, 76 L.Ed.2d 648 (1983). Therefore, a Bivens

action requiresthe plaintiffto "claima deprivation of a constitutionalright." Zernial v. United States,

714 F.2d 431, 435 (5th Cir.1983). This action extends to alleged violations of the First Amendment

and to deprivations of Fifth Amendment due process rights. Bush, 462 U.S. 367, 103 S.Ct. 2404

(First Amendment); Butz v. Economou, 438 U.S. 478, 98 S.Ct. 2894, 57 L.Ed.2d 895 (1978) (Fifth

Amendment). The Contractors' Bivens claims are based on two theories: that they have a right to

self-marketing and they have been deprived of that right without procedural due process in

contravention of the Fifth Amendment; and that this denial of self-marketing is in retaliation against

the Contractors, and is an attempt to deny them access to the courts as is their right under the First

Amendment.

To succeed on a procedural due process claim, the Contractors must show they had a

"cognizable property or liberty interest," and such a property interest must be "a legitimate claim of

entitlement." Broadway v. Block, 694 F.2d 979, 985 (5thCir.1982). Here, there exists no legitimate

claim of entitlement. The Contractors have no right to access of Corps personnel for this purpose.
 

16In their opaque brief, the Contractors make some murky allusions to the possibility that their

First Amendment rights have also been violated by the mere fact that Page and Green will not

speak to them. They cite no authority for this theory, and we will not root about in the case law

seeking support for it. Cf. United States v. Dunkel, 927 F.2d 955, 956 (7th Cir.1991) ("Judges

are not like pigs, hunting for truffles buried in briefs."). Furthermore, their amended complaint

does not offer this theory as a basis for recovery, and they did not argue this theory below. 

Therefore, the Contractors have waived any claim on this basis. 

 

17The Contractors now contend that this paper is hearsay, and cannot be relied on by the

district court in rendering summary judgment. However, they did not raise this hearsay objection

below, so the error, if any, is waived. See United States v. Maddox, 492 F.2d 104, 107 (5th Cir.),

48 C.F.R. 19.803(c). As described above, under the 8(a) program, the SBA, and not the individual

minority contractor, is authorized to contract as the prime contractor with the procurement agency.

Id. The SBA may, in its discretion, allow the individual minority contractor to negotiate directly with

the procurement agency, and familiarize that agencywith its capabilitiesfor future contracts; but the

SBA is not required to do so. 48 C.F.R. §§ 19.803(c), 19.804-2(a)(12). These direct

communications through "self-marketing" are not required by any statute or regulation. As found

by the district court, the Contractors are allowed to self-market at the sufferance of Corps personnel,

and theCorps has complete discretion concerning whether it will give such accessto the Contractors.

Under these facts no liberty or property interest isimplicated. The district court did not err in finding

that the Contractors had failed to present a violation of procedural due process.

The Contractors also contend that the denial ofself-marketing isin retaliation for the lawsuit

and is designed to chill access to the courts of the United States in violation of the Contractors' First

Amendment rights.16 Because of the preeminent place that the First Amendment occupies in our

constitutional jurisprudence, the Contractors need not prove that in being denied the right to

self-market, they have been denied a property right or liberty interest orsome other independent legal

right. See Connick v. Myers, 461 U.S. 138, 103 S.Ct. 1684, 75 L.Ed.2d 708 (1983). But they still

must show a constitutional violation. Here, the fact that the contracting officers' refused to speak to

the Contractors during the pendency of this suit does not indicate that such refusal was made in an

effort to chill the Contractors' accessto the courts or to punish them for having brought suit. Rather,

such a refusal was made pursuant to an Information Paper that instructed agency procurement

officers to avoid contact with contractors during the pendency of their litigation with the agency.17
cert. denied, 419 U.S. 851, 95 S.Ct. 92, 42 L.Ed.2d 82 (1974) (holding that "[a] rule of evidence

not invoked is waived"). 

 

18Furthermore, as to both Bivens claims, the Contractors sought monetary damages against

Page and Green. However, as pointed out by the district court, the Contractors introduced no

evidence showing that Page's and Green's refusal to speak with the Contractors led to the

Contractors being denied any contracts. In an earlier suit against the Corps concerning the

discretionary award of contracts, this Court noted that the plaintiffs wisely abstained from

pressing any claims for monetary damages because, "Such a claim would force upon them the

Herculean task of proving the Corps actually would have awarded them the contracts in question

in the absence of the claimed violations." Valley I, 714 F.2d at 29 n. 4. In the case sub judice,

not only have the Contractors failed to show that the Corps would have awarded them contracts if

the Contractors were allowed to self-market, but they have also failed to describe any particular

contracts as to which they were in contention. Therefore, for this reason also, the district court

did not err in finding that the Contractors were not entitled to monetary damages based on their

Bivens claims. 

This paper was issued on February 6, 1990—months before the suspension—and was apparently

distributed by the Army's general counsel to all defense procurement agencies. It notes that contact

should be avoided so that the procurement officer will not inadvertently "give the contractor any

ammunition to weaken the Government's position. Any such statements may be used by the

contractor in litigation and may ultimately lead to the depositions of the officials who make the

statements and their subsequent testimony." A government employee who is a potential witness is

not improperly chilling access to the courts or retaliating for use of the judicial system when he

refusesto speak to a party concerning a matter that isrelated to the gravamen ofthat party'slitigation

against him or his employer. Page and Green did not deny the Contractors their constitutional rights

under the First Amendment. There is nothing which would sustain a finding that Page and Green's

actions—perhaps more accurately, their inactions—were retaliatory or motivated by considerations

other than those of the Information Paper or that they were a pretext for unconstitutionalretaliation.

Consequently, "any assertion that [the officers'] actions ... were retaliatory can only be speculation."

Bowles v. U.S. Army Corps of Engineers, 841 F.2d 112, 117 (5th Cir.), cert. denied, 488 U.S. 803,

109 S.Ct. 33, 102 L.Ed.2d 13 (1988). The district court did not err in finding that since access for

self-marketing was discretionary and that the denial of self-marketing was based on official army

policy, it was not unconstitutional or "retaliatory" for Corps personnel to avoid the plaintiffs during

the litigation.18
V. Attorneys' Fees

The Contractors argue that they are entitled to attorneys'fees under 28 U.S.C. § 2412(d) and

42 U.S.C. § 1988 because by filing the lawsuit and vigorously prosecuting it, they forced the Corps

to resume the 8(a) program. Allegedly, these actions qualify them to be considered as prevailing

parties because they "acted as a catalyst in prompting the opposing party to make amends." Ramon

by Ramon v. Soto, 916 F.2d 1377, 1384 (9th Cir.1989). We reject these contentions.

Section 1988 can serve asthe basisfor the recovery of attorneys' fees only if the Contractors

can show that they have presented a substantial racial discrimination claim. See Kelly v. City of

Leesville, 897 F.2d 172, 177 (5thCir.1990); McDonald v. Doe, 748 F.2d 1055, 1077 (5thCir.1984)

(noting that section 1988 "was adopted because the actionsin which fees are allowed vindicate rights

based on the federal constitution or federal statutes. If it is determined that no constitutional right

was violated, the predicate for the award of fees vanishes."). However, as we have discussed above,

the Contractors have wholly failed to make out a claim for racial discrimination. At best, the

Contractors have alleged that the Corpssuspended the 8(a) program for an inadequate reason: their

fear that the Fordice decision will lead to further lawsuits or potential liability concerning their

participation in the 8(a) program. But, the Corps' suspension of the program based on its reaction

to the Fordice decision does not somehow transmute that motivation into racialdiscrimination. Even

assuming that the Contractors' actions caused the resumption of the 8(a) program, since the

suspension was not based on any racial animus, the Contractors could not recover under section

1988(b) and therefore cannot be considered prevailing parties under that statute. See McQuiston v.

Marsh, 707 F.2d 1082, 1085 (9th Cir.1983) (finding that an unsuccessful bidder on a government

contract could be a prevailing party under section 2412 based on his claim of bad faith, but not under

section 1988 because he could not prevail on his discrimination claim).

The Contractors can recover under the Equal Access to Justice Act codified at section

2412(d)(1)(A) only if they show: (1) that they are a "prevailing party"; (2) that the Government's

position was not "substantially justified"; and (3) that no "special circumstances make an award
 

19We note that the Ramon court decided only the first factor and held that the plaintiffs were

entitled to fees "unless the government's position was substantially justified or special

circumstances would make an award unjust." Ramon, 916 F.2d at 1384. Therefore, even if the

Contractors can be classified as "catalysts" for the Defendants' resumption of the 8(a) program,

they still must satisfy the remaining requirements of section 2412(d). 

unjust." Perales v. Casillas, 950 F.2d 1066, 1072 (5th Cir.1992).19 The Contractors have not

alleged any facts showing that the Defendants' position was not substantially justified. Since the

Defendants' abeyance was based on the adverse Fordice decision, we find that their position

concerning the suspension of the 8(a) program pending further guidance was substantially justified.

Therefore, the district court did not err in denying attorneys' fees to the Contractors.

VI. Change of Venue

 The Contractors contend that the district court erred in granting the Defendants' change of

venue motion as to Keeler's Cotton Meade project claims. However, the grant of a change of venue

motion is an interlocutory order and is not reviewable. See Louisiana Ice Cream Distributors v.

Carvel Corp., 821 F.2d 1031, 1033-34 (5th Cir.1987); Garner v. Wolfinbarger, 433 F.2d 117, 120

(5th Cir.1970); Chas. Pfizer & Co. v. Olin Mathieson Chem. Corp., 225 F.2d 718 (5th Cir.1955).

Keeler'sCottonMeade project claims have been severed fromthis action and transferred to a different

forum. These claims are unreviewable in this appeal.

Conclusion

Based on the foregoing, the district court's orders are

AFFIRMED.