Office Lease


 Exhibit 10.1 
 OFFICE LEASE 
 This Office Lease (this “Lease”),
dated as of the date set forth in Section 1.1, is made by and between CA-10880 WILSHIRE LIMITED PARTNERSHIP, a Delaware limited partnership (“Landlord”), and PUMA BIOTECHNOLOGY, INC., a Delaware corporation
(“Tenant”). The following exhibits are incorporated herein and made a part hereof: Exhibit A (Outline of Premises); Exhibit B (Work Letter); Exhibit C (Form of
Confirmation Letter); Exhibit D (Rules and Regulations); Exhibit E (Judicial Reference); Exhibit F (Additional Provisions); Exhibit G (Asbestos Notification); Exhibit
H (Outline and Location of Temporary Space); and Exhibit I (Form of Letter of Credit). 
  

	1	BASIC LEASE INFORMATION 

  

							
	 1.1
	 	Date:	 		 	October 4, 2011
				
	 1.2    
	 	Premises.	 		 	
				
		 	1.2.1	 	“Building”:	 	10880 Wilshire Boulevard, Los Angeles, California, commonly known as 10880 Wilshire Boulevard.
				
		 	1.2.2	 	“Premises”:	 	Subject to Section 2.1.1, 13,254 rentable square feet of space located on the 21st floor of the Building and commonly known as Suite No. 2150, the outline and location of which is set forth in
Exhibit A. If the Premises includes any floor in its entirety, all corridors and restroom facilities located on such floor shall be considered part of the Premises.
				
		 	1.2.3	 	“Property”:	 	The Building, the parcel(s) of land upon which it is located, and any parking facilities and other improvements serving the Building and the parcel(s) of land upon which such
parking facilities and other improvements are located.
				
		 	1.2.4	 	“Project”:	 	The Property or, any project containing the Property and any other land, buildings or other improvements.
				
	 1.3    
	 	Term	 		 	
				
		 	1.3.1	 	Term:	 	The term of this Lease (the “Term”) shall commence on the Commencement Date and end on the Expiration Date (or any earlier date on which this Lease is terminated
as provided herein).
				
		 	1.3.2	 	“Commencement Date”:	 	The earlier of (i) the first date on which Tenant conducts business in the Premises (excluding the Temporary Space) pursuant to this Lease, or (ii) the date on which
the Premises is Ready for Occupancy (defined in Exhibit B), which is anticipated to be November 1, 2011
				
		 	1.3.3	 	“Expiration Date”:	 	The last day of the 84th full calendar month commencing on or after the Commencement Date.
			
	 1.4    
	 	    “Base Rent”:	 	


  
 1 








									
	Period During Term	  	Annual Base Rent
Per Rentable
Square Foot	 	  	Monthly
Installment
of Base Rent	 
	 Commencement Date through last day of 12th full calendar month of Term
	  	$	40.20	  	  	$	44,400.90	  
	 13th through 24th full calendar month of Term
	  	$	41.41	  	  	$	45,737.35	  
	 25th through 36th full calendar month of Term
	  	$	42.65	  	  	$	47,106.93	  
	 37th through 48th full calendar month of Term
	  	$	43.93	  	  	$	48,520.69	  
	 49th through 60th full calendar month of Term
	  	$	45.25	  	  	$	49,978.63	  
	 61st through 72nd full calendar month of Term
	  	$	46.60	  	  	$	51,469.70	  
	 73rd full calendar month of Term through Expiration Date
	  	$	48.00	  	  	$	53,016.00	  

 Base Rent Abatement. Notwithstanding anything in this Lease to the contrary,
so long as Tenant is not in Default (as defined in Section 19) under this Lease, Tenant shall be entitled to an abatement of Base Rent in the amount of $44,400.90 per month applicable to the second (2nd), third (3rd), fourth (4th), fifth (5th), sixth (6th) and eleventh (11th) full calendar months of the Term. The total amount of Base Rent abated in accordance with the foregoing shall
equal $266,405.40 (the “Abated Base Rent”). Only Base Rent shall be abated pursuant to this Section, and all Additional Rent (as defined in Section 3 below) and other costs and charges specified in this Lease
shall remain as due and payable pursuant to the provisions of this Lease. 
  

							
		 	1.5	 	“Base Year” for Expenses:	 	
		 		 		 	Calendar year 2012.
		 		 	“Base Year” for Taxes:	 	
		 		 		 	Calendar year 2012.
				
		 	1.6 	 	“Tenant’s Share”:	 	2.2542% (based upon a total of 587,971 rentable square feet in the Building).
				
		 	1.7 	 	“Permitted Use”:	 	General office use consistent with a first-class office building; provided that in no event shall the Premises, or any portion of the Premises, be used for the primary use of (i)
retail sale of food and beverages, or (ii) a retail commercial printing service.
				
		 	1.8. 	 	“Security Deposit”:	 	$0, as more particularly described in Section 21.
				
		 		 	Prepaid Base Rent:	 	$44,400.90, as more particularly described in Section 3.
				
		 		 	Letter of Credit:	 	$1,000,000, as more particularly described in, and subject to reduction pursuant to, Section 6 of Exhibit
F.


  
 2 








							
		 	1.9	 	Parking:	 	 Tenant shall have the right, but not the obligation, to lease up to 39 unreserved parking passes; provided, however, Tenant
may convert up to three (3) of such 39 unreserved passes into three (3) reserved parking passes in the Parking Facility (as defined in Section 24). Prior to the Commencement Date, Tenant shall notify Landlord in writing of the number
of unreserved and reserved parking passes which Tenant initially elects to lease during the Term. Thereafter, Tenant may increase or decrease the number of reserved and unreserved parking passes to be used by Tenant pursuant to this Section
1.9 upon a minimum of 30 days prior written notice to Landlord, provided that it Tenant fails to continuously lease any reserved passes, Tenant’s right to thereafter lease such unleased reserved passes shall be subject to availability as
determined by Landlord in its reasonable discretion.
  
 Tenant shall pay
Landlord the current rate of $180.00 per unreserved parking pass per month, plus applicable taxes, if any, and $275.00 per unreserved parking pass per month, plus applicable taxes, if any. Such rates shall be subject to increase from
time to time to reflect the prevailing market rates consistently charged in the Parking Facility.
  
 In the event that Tenant expands the Premises, Tenant’s parking pass allocation shall increase in proportion to the increase in Tenant’s rentable square footage of the Premises.

 
 Tenant may, from time to time request additional parking passes, and, subject to
availability as determined by Landlord in its reasonable discretion, Landlord shall provide the same. Any such additional parking passes shall be provided and used on a month-to-month basis (subject to termination by either party), and otherwise on
the foregoing terms and provisions, and at such prevailing monthly parking charges as shall be established from time to time.

				
		 	1.10	 	Address of Tenant:	 	 Before the Commencement Date:
  

PUMA BIOTECHNOLOGY, INC.
 10940 Wilshire
Boulevard
 Suite 600
 Los Angeles, CA
90024
 Attn.: Chief Executive Officer
  

From and after the Commencement Date: the Premises, Attn.: Chief Executive
Officer.



  
 3 








							
		 	1.11	 	Address of Landlord:	 	 CA-10880 Wilshire Limited Partnership
 c/o Equity Office
 10880 Wilshire Boulevard
 Suite 1010
 Los Angeles, CA 90024
 Attention: Property Manager
  

with copies to:
  
 CA-10880 Wilshire Limited Partnership
 c/o Equity Office

Two North Riverside Plaza
 Suite 2100

Chicago, IL 60606
 Attention: Managing
Counsel
  
 and

 
 Equity Office
 Two North Riverside Plaza
 Suite 2100
 Chicago, IL 60606
 Attn: Lease Administration

				
		 	1.12	 	Broker(s):	 	Weiss/L.A. Realty Partners (“Tenant’s Broker”), representing Tenant, and Team WW/L.A. Realty Partners (“Landlord’s
Broker”), representing Landlord.
				
		 	1.13	 	Building HVAC Hours and Holidays:	 	“Building HVAC Hours” means 8:00 a.m. to 6:00 p.m., Monday through Friday and 9:00 a.m. to 1:00 p.m. on Saturdays, excluding the day of
observation of New Year’s Day, Presidents Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day, Christmas Day, and, at Landlord’s reasonable discretion, any other locally or nationally recognized holiday that is observed by
other buildings comparable to and in the vicinity of the Building (collectively, “Holidays”).
				
		 	1.14 	 	“Transfer Radius”:	 	NONE
				
		 	1.15 	 	“Tenant Improvements”:	 	Defined in Exhibit B.
		 		 		 	
		 	1.16 	 	“Guarantor”:	 	As of the date hereof, there is no Guarantor.

  

	2	PREMISES AND COMMON AREAS. 


2.1 The Premises. 
 2.1.1 Subject to the terms hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. Landlord and Tenant acknowledge that the rentable square footage of
the Premises is as set forth in Section 1.2.2 and the rentable square footage of the Building is as set forth in Section 1.6. Landlord represents to Tenant that the rentable square footage of the Premises and Building has
been calculated pursuant to the Standard Method for Measuring Floor Area in Office Building, ANSI Z65.1 – 1996 and its accompanying guidelines (“BOMA”) and shall not be subject to remeasurement during the initial Term. At any
time Landlord may deliver to Tenant a notice substantially in the form of Exhibit C, as a confirmation of the information set forth therein. Tenant shall execute and return (or, by notice to Landlord, reasonably object to) such
notice within 10 days after receiving it, and if Tenant fails to do so, Tenant shall be deemed to have executed and returned it without exception. 
 2.1.2 Except as expressly provided herein, the Premises is accepted by Tenant in its condition and configuration existing on the date hereof (or in such other condition and configuration as any existing
tenant of the Premises may cause to exist in accordance with its lease), without any obligation of Landlord to perform or pay for any alterations to the Premises, and without any representation or warranty regarding the condition of the Premises,
the Building or the Project or their suitability for Tenant’s business. By taking possession of the Premises pursuant to this Lease, Tenant 

  
 4 







 
acknowledges that the Premises and the Building are then in the condition and configuration required hereunder. As of the date of this Lease, Landlord represents that Base Building electrical,
HVAC (i.e., heating, ventilation and air conditioning) and plumbing systems are in good working order. 
 2.2 Common
Areas. Tenant may use, in common with Landlord and other parties and subject to the Rules and Regulations (defined in Exhibit D), any portions of the Property that are designated from time to time by Landlord for such use
(the “Common Areas”). 
 3     RENT. Tenant shall pay all Base Rent and Additional Rent
(defined below) (collectively, “Rent”) to Landlord or Landlord’s agent, without prior notice or demand or any setoff or deduction (except as otherwise expressly provided for in this Lease), at the place Landlord may designate
from time to time. As used herein, “Additional Rent” means all amounts, other than Base Rent, that Tenant is required to pay Landlord hereunder. Monthly payments of Base Rent and monthly payments of Additional Rent for Expenses
(defined in Section 4.2.2), Taxes (defined in Section 4.2.3) and parking (collectively, “Monthly Rent”) shall be paid in advance on or before the first day of each calendar month during the Term; provided,
however, that the installment of Base Rent for the first full calendar month for which Base Rent is payable hereunder shall be paid upon Tenant’s execution and delivery hereof. Except as otherwise provided herein, all other items of Additional
Rent shall be paid within 30 days after Landlord’s request for payment. Rent for any partial calendar month shall be prorated based on the actual number of days in such month. Without limiting Landlord’s other rights or remedies,
(a) if any installment of Rent is not received by Landlord or its designee within five (5) business days after its due date, Tenant shall pay Landlord a late charge equal to five percent (5%) of the overdue amount; and (b) any
Rent that is not paid within 10 days after its due date shall bear interest, from its due date until paid, at the lesser of 10% per annum or the highest rate permitted by Law (defined in Section 5). Tenant’s covenant to
pay Rent is independent of every other covenant herein. 
  

	4	EXPENSES AND TAXES. 

 4.1
General Terms. In addition to Base Rent, Tenant shall pay, in accordance with Section 4.4, for each Expense Year (defined in Section 4.2.1), an amount equal to the sum of (a) Tenant’s Share of any
amount (the “Expense Excess”) by which Expenses for such Expense Year exceed Expenses for the Base Year, plus (b) Tenant’s Share of any amount (the “Tax Excess”) by which Taxes for such Expense Year exceed
Taxes for the Base Year. No decrease in Expenses or Taxes for any Expense Year below the corresponding amount for the Base Year shall entitle Tenant to any decrease in Base Rent or any credit against amounts due hereunder. Tenant’s Share of the
Expense Excess and Tenant’s Share of the Tax Excess for any partial Expense Year shall be prorated based on the number of days in such Expense Year. 
 4.2 Definitions. As used herein, the following terms have the following meanings: 
 4.2.1 “Expense Year” means each calendar year (other than the Base Year and any preceding calendar year) in which any portion of the Term occurs. 

4.2.2 “Expenses” means all expenses, costs and amounts that Landlord pays or accrues during the Base Year or any Expense
Year because of or in connection with the ownership, management, maintenance, security, repair, replacement, restoration or operation of the Property. Landlord shall act in a reasonable manner in incurring Expenses. Expenses shall include
(i) the cost of supplying all utilities, the cost of operating, repairing, maintaining and renovating the utility, telephone, mechanical, sanitary, storm-drainage, and elevator systems, and the cost of maintenance and service contracts in
connection therewith; (ii) the cost of licenses, certificates, permits and inspections, the cost of contesting any Laws that may affect Expenses, and the costs of complying with any governmentally-mandated transportation-management or similar
program; (iii) the cost of all insurance premiums and deductibles; (iv) the cost of landscaping and relamping; (v) the cost of parking-area operation, repair, restoration, and maintenance; (vi) a management fee in the amount
(which is hereby acknowledged to be reasonable) of three percent (3%) of gross annual receipts from the Building (excluding the management fee), together with other fees and costs, including consulting fees, legal fees and accounting fees, of
all contractors and consultants in connection with the management, operation, maintenance and repair of the Property; (vii) payments under any equipment-rental agreements and the fair rental value of any management office space;
(viii) wages, salaries and other compensation, expenses and benefits, including taxes levied thereon, of all persons engaged in the operation, maintenance and security of the Property, and costs of training, uniforms, and employee enrichment
for such persons; (ix) the costs of operation, repair, maintenance and replacement of all systems and equipment (and components thereof) of the Property; (x) the cost of janitorial, alarm, security and other services, replacement of wall
and floor coverings, ceiling tiles and fixtures in Common Areas, maintenance and replacement of curbs and walkways, repair to roofs and re-roofing; (xi) rental or acquisition costs of supplies, tools, equipment, materials and personal property
used in the maintenance, operation and repair of the Property; (xii) the cost of capital improvements or any other items that are (A) intended to effect economies in the operation or maintenance of the Property, reduce current or future
Expenses, (B) INTENTIONALLY OMITTED, or (C) required under any Law; (xiii) the cost of tenant-relation programs reasonably established by Landlord; and (xiv) payments under any existing or future reciprocal easement
agreement, transportation management agreement, cost-sharing agreement or other covenant, condition, restriction or similar instrument affecting the Property. 

  
 5 







 Notwithstanding the foregoing, Expenses shall not include: (a) capital expenditures not
described in clauses (xi) or (xii) above (in addition, any capital expenditure shall be included in Expenses only if paid or accrued after the Base Year and shall be amortized (including actual or reasonably imputed interest on the
amortized cost) over such period of time as Landlord shall reasonably determine, only the amortization applicable to a particular Expense Year shall be included in Expenses for such Expense Year, and in no event shall the amortization in any Expense
Year of the costs incurred by Landlord for capital improvements to effect economies in the operation or maintenance of the Property or reduce current or future Expenses exceed the cost savings, as reasonably estimated by Landlord, for such Expense
Year as the result thereof; (b) depreciation; (c) interest, principal, amortization, fees and charges relating to indebtedness on the Building or Project, ground rent payments or other non-operating debts of Landlord; (d) costs of
repairs to the extent Landlord is reimbursed by insurance or condemnation proceeds; (e) except as provided in clause (xiii) above, costs of leasing space in the Building, including brokerage commissions, lease concessions, rental
abatements and construction allowances granted to specific tenants; (f) costs of selling, financing or refinancing the Building; (g) fines, penalties or interest resulting from late payment of any Expenses; (h) organizational expenses
of creating or operating the entity that constitutes Landlord; (i) damages paid to Tenant hereunder or to other tenants of the Building under their respective leases; (j) costs relating to services and other items that exclusively benefit
particular tenants of the Building or Project other than Tenant and/or costs relating to services provided to other tenants for which Landlord is entitled to be reimbursed by such tenants as an additional or extra charge over and above the rental
payable by such tenants; (k) advertising and promotional expenses; (l) costs arising from the negligence or willful misconduct of Landlord or its agents, employees or contractors; (m) costs incurred as the result of the presence of or
to remediate or encapsulate any asbestos-containing materials or any other hazardous materials or substances in or about the Building or the Project, (n) costs and the overhead and profit increment paid to Landlord, to affiliates or partners of
Landlord, partners or affiliates of such partners, or affiliates of Landlord for goods and/or services in the Building to the extent the same exceeds the costs or the overhead and profit increment, as the case may be, of such goods and/or services
rendered by unaffiliated third parties on a competitive basis in comparable buildings; (o)costs incurred in connection with the original construction of the Building or Project or to remedy or repair latent defects in the original design or
construction of the Building; (p) costs associated with the operation of the business of the partnership or entity which constitutes the Landlord, as the same are distinguished from the costs of operation of the Property, including partnership
accounting and legal matters, general corporate overhead and general administrative expenses, advertising and promotional expenditures; (q) the wages and benefits of any employee above the level of General Manager or any employee who does not
devote substantially all of his or her employed time to the Project, unless such wages and benefits of employees are prorated to reflect time spent on operating and managing the Project vis-à-vis time spent on matters unrelated to operating
and managing the Project; (r) rentals and other expenses incurred in leasing air conditioning systems, elevators or other equipment ordinarily considered to be of a capital nature if purchased, except equipment which is used in providing
janitorial or similar services and which is not affixed to the Building and equipment rented to remedy or ameliorate an emergency condition; (s) costs to replace the roof or repair or replace the foundation of the Building; (t) any bad
debt loss, rent loss or reserve for bad debts or rent losses; (u) except as provided herein with respect to parking, any compensation and benefits paid to clerks, attendants or other persons in commercial concessions operated by Landlord in the
Building or Project; (v) costs for which any other tenant of the Building or Project is obligated to pay directly or to separately reimburse Landlord therefore; (w) costs, other than those incurred for normal cleaning, maintenance or
repair, for sculptures, paintings or other objects of art; (x) costs arising from the gross negligence or willful misconduct of Landlord or its agents, employees, vendors or contractors, and Landlord’s costs, including but not limited to
attorneys’ fees, of performing any indemnity obligations to tenants under tenant leases; (y) costs incurred by Landlord due to the violation by Landlord or any tenant of the terms and conditions of any lease of space in the Building;
(z) costs arising from Landlord’s political or charitable contributions; and (aa) any retroactive adjustment of Expenses for any Expense Year ending more than two (2) years prior to the date of such retroactive adjustment. 

If, during any portion of the Base Year or any Expense Year, the Building is not at least 95% occupied (or a service provided by Landlord
to tenants of the Building generally is not provided by Landlord to a tenant that provides such service itself, or any tenant of the Building is entitled to free rent, rent abatement or the like), Expenses for such year shall be determined as if the
Building had been at least 95% occupied (and all services provided by Landlord to tenants of the Building generally had been provided by Landlord to all tenants, and no tenant of the Building had been entitled to free rent, rent abatement or the
like) during such portion of such year. If insurance, security or utility costs for any Expense Year are less than insurance, security or utility costs, respectively, for the Base Year, then, for purposes of determining Expenses for such Expense
Year, such costs for such Expense Year shall be deemed to be increased so as to be equal to such corresponding costs for the Base Year. Notwithstanding any contrary provision hereof, Expenses for the Base Year shall exclude (a) any market-wide
cost increases resulting from extraordinary circumstances, including Force Majeure (defined in Section 25.2), boycotts, strikes, conservation surcharges, embargoes or shortages, and (b) the cost of any repair or replacement that
Landlord reasonably expects will not recur on an annual or more frequent basis. 
 4.2.3 “Taxes” means
all federal, state, county or local governmental or municipal taxes, fees, charges, assessments, levies, licenses or other impositions, whether general, special, ordinary or 

  
 6 







 
extraordinary, that are paid or accrued during the Base Year or any Expense Year (without regard to any different fiscal year used by such governmental or municipal authority) because of or in
connection with the ownership, leasing or operation of the Property. Taxes shall include (a) real estate taxes; (b) general and special assessments; (c) transit taxes; (d) leasehold taxes; (e) personal property taxes imposed
upon the fixtures, machinery, equipment, apparatus, systems, appurtenances, furniture and other personal property used in connection with the Property; (f) any tax on the rent, right to rent or other income from any portion of the Property or
as against the business of leasing any portion of the Property; (g) any assessment, tax, fee, levy or charge imposed by any governmental agency, or by any non-governmental entity pursuant to any private cost-sharing agreement, in order to fund
the provision or enhancement of any fire-protection, street-, sidewalk- or road-maintenance, refuse-removal or other service that is (or, before the enactment of Proposition 13, was) normally provided by governmental agencies to property owners
or occupants without charge (other than through real property taxes); and (h) any assessment, tax, fee, levy or charge allocable or measured by the area of the Premises or by the Rent payable hereunder, including any business, gross income,
gross receipts, sales or excise tax with respect to the receipt of such Rent. Any costs and expenses (including reasonable attorneys’ and consultants’ fees) incurred in attempting to protest, reduce or minimize Taxes shall be included in
Taxes for the year in which they are incurred. Notwithstanding any contrary provision hereof, Taxes shall be determined without regard to any “green building” credit and shall exclude (i) all excess profits taxes, franchise taxes,
gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state income taxes, and other taxes to the extent applicable to Landlord’s general or net income (as opposed to rents, receipts or income attributable
to operations at the Property), (ii) any Expenses, (iii) any items required to be paid by Tenant under Section 4.5, and (iv) tax penalties incurred as a result of Landlord’s failure to timely make payments and/or to
file any tax returns. All assessments for Taxes which are not specifically charged to Tenant which can be paid by Landlord in installments without the imposition of fees, penalties or interest, shall be paid by Landlord in the maximum number of
installments that are permitted by applicable Laws without the imposition of fees, penalties or interest and not included Taxes except in the Expense Year in which the assessment installment is actually paid; provided, however, that if the
prevailing practice in the comparable class A buildings in Los Angeles is to pay such assessments on an earlier basis, and Landlord pays on such earlier basis, such assessments shall be included in Taxes as paid by Landlord. 

4.3 Allocation. Landlord, in its reasonable discretion, may equitably allocate Expenses among office, retail or other
portions or occupants of the Property. If Landlord incurs Expenses or Taxes for the Property together with another property, Landlord shall equitably allocate such shared amounts between the Property and such other property. 

4.4 Calculation and Payment of Expense Excess and Tax Excess. 

4.4.1 Statement of Actual Expenses and Taxes; Payment by Tenant. Landlord shall endeavor to give to Tenant, after the end
of each Expense Year, a statement (the “Statement”) setting forth the actual Expenses, Taxes, Expense Excess and Tax Excess for such Expense Year. If the amount paid by Tenant for such Expense Year pursuant to
Section 4.4.2 is less or more than the sum of Tenant’s Share of the actual Expense Excess plus Tenant’s Share of the actual Tax Excess (as such amounts are set forth in such Statement), Tenant shall pay Landlord the amount of
such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however, that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay
Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after delivery of such Statement. Any failure of Landlord to timely deliver the Statement for any Expense
Year shall not diminish either party’s rights under this Section 4. 
 4.4.2 Statement of Estimated
Expenses and Taxes. Landlord shall endeavor to give to Tenant, for each Expense Year, a statement (the “Estimate Statement”) setting forth Landlord’s reasonable estimates of the Expenses, Taxes, Expense
Excess (the “Estimated Expense Excess”) and Tax Excess (the “Estimated Tax Excess”) for such Expense Year. Upon receiving an Estimate Statement, Tenant shall pay, with its next
installment of Base Rent, an amount equal to the excess of (a) the amount obtained by multiplying (i) the sum of Tenant’s Share of the Estimated Expense Excess plus Tenant’s Share of the Estimated Tax Excess (as such amounts are
set forth in such Estimate Statement), by (ii) a fraction, the numerator of which is the number of months that have elapsed in the applicable Expense Year (including the month of such payment) and the denominator of which is 12, over
(b) any amount previously paid by Tenant for such Expense Year pursuant to this Section 4.4.2. Until Landlord delivers a new Estimate Statement (which Landlord may do at any time), Tenant shall pay monthly, with the monthly Base
Rent installments, an amount equal to one-twelfth (1/12) of the sum of Tenant’s Share of the Estimated Expense Excess plus Tenant’s Share of the Estimated Tax Excess, as such amounts are set forth in the previous Estimate Statement.
Any failure of Landlord to timely deliver any Estimate Statement shall not diminish Landlord’s rights to receive payments and revise any previous Estimate Statement under this Section 4. 

4.4.3 Retroactive Adjustment of Taxes. Notwithstanding any contrary provision hereof, if, after Landlord’s delivery of
any Statement, an increase or decrease in Taxes occurs for the applicable Expense Year or for the Base Year (whether by reason of reassessment, error, or otherwise), Taxes for 

  
 7 







 
such Expense Year or the Base Year, as the case may be, and the Tax Excess for such Expense Year shall be retroactively adjusted. If, as a result of such adjustment, it is determined that Tenant
has under- or overpaid Tenant’s Share of such Tax Excess, Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the Rent then or next due hereunder; provided, however,
that if this Lease has expired or terminated and Tenant has vacated the Premises, Tenant shall pay Landlord the amount of such underpayment, or Landlord shall pay Tenant the amount of such overpayment (less any Rent due), within 30 days after
such adjustment is made. 
 4.5 Charges for Which Tenant Is Directly Responsible. Tenant shall pay, 10 days
before delinquency, any taxes levied against Tenant’s equipment, furniture, fixtures and other personal property located in or about the Premises. If any such taxes are levied against Landlord or its property (or if the assessed value of
Landlord’s property is increased by the inclusion therein of a value placed upon such equipment, furniture, fixtures or other personal property of Tenant), Landlord may (upon prior notice to Tenant) pay such taxes (or such increased assessment)
regardless of their (or its) validity, in which event Tenant, upon demand, shall repay to Landlord the amount so paid. If the Leasehold Improvements (defined in Section 7.1) are assessed for real property tax purposes at a valuation
higher than the valuation at which tenant improvements conforming to Landlord’s “building standard” in other space in the Building are assessed, the Taxes levied against Landlord or the Property by reason of such excess assessed
valuation shall be deemed taxes levied against Tenant’s personal property for purposes of this Section 4.5. Notwithstanding any contrary provision hereof, Tenant shall pay, 10 days before delinquency, (i) any rent tax,
sales tax, service tax, transfer tax or value added tax, or any other tax respecting the rent or services described herein or otherwise respecting this transaction or this Lease; and (ii) any taxes assessed upon the possession, leasing,
operation, management, maintenance, alteration, repair, use or occupancy by Tenant of any portion of the Property. 
 4.6
Books and Records. Within 180 days after receiving any Statement (the “Review Notice Period”), Tenant may give Landlord notice (“Review Notice”) stating that Tenant elects to review and/or audit
Landlord’s calculation of the Expense Excess and/or Tax Excess for the Expense Year to which such Statement applies and identifying with reasonable specificity the records of Landlord reasonably relating to such matters that Tenant desires to
review and/or audit. Within a reasonable time after receiving a timely Review Notice (and, at Landlord’s option, an executed confidentiality agreement as described below), Landlord shall deliver to Tenant, or make available for inspection at a
location reasonably designated by Landlord, copies of such records. Within 60 days after such records are made available to Tenant (the “Objection Period”), Tenant may deliver to Landlord notice (an “Objection
Notice”) stating with reasonable specificity any objections to the Statement, in which event Landlord and Tenant shall work together in good faith to resolve Tenant’s objections. Tenant may not deliver more than one Review Notice or
more than one Objection Notice with respect to any Expense Year. If Tenant fails to give Landlord a Review Notice before the expiration of the Review Notice Period or fails to give Landlord an Objection Notice before the expiration of the Objection
Period, Tenant shall be deemed to have approved the Statement. Notwithstanding any contrary provision hereof, Landlord shall not be required to deliver or make available to Tenant records relating to the Base Year, and Tenant may not object to
Expenses or Taxes for the Base Year, other than in connection with the first review and/or audit for an Expense Year performed by Tenant pursuant to this Section 4.6. If Tenant retains an agent to review Landlord’s records, the
agent must be with a CPA firm licensed to do business in the State of California and its fees shall not be contingent, in whole or in part, upon the outcome of the review and/or audit. Tenant shall be responsible for all costs of such review and/or
audit; provided, however, that if it is determined by Landlord and Tenant, or if it is determined in any action or proceeding arising from a dispute hereunder, that the sum of Expenses and Taxes for the Expense Year in question was overstated by
more than five percent (5%), Landlord, within 30 days after receiving paid invoices therefor from Tenant, shall reimburse Tenant for the reasonable amounts paid by Tenant to third parties in connection with such review and/or audit. The records and
any related information obtained from Landlord shall be treated as confidential, and as applicable only to the Premises, by Tenant, its auditors, consultants, and any other parties reviewing the same on behalf of Tenant (collectively,
“Tenant’s Auditors”). Before making any records available for review, Landlord may require Tenant and Tenant’s Auditors to execute a reasonable confidentiality agreement, in which event Tenant shall cause the same to be
executed and delivered to Landlord within 30 days after receiving it from Landlord, and if Tenant fails to do so, the Objection Period shall be reduced by one day for each day by which such execution and delivery follows the expiration of such
30-day period. Notwithstanding any contrary provision hereof, Tenant may not examine Landlord’s records or dispute any Statement if any Rent remains unpaid past its due date. If, for any Expense Year, it is determined by Landlord and Tenant, or
if it is determined in any action or proceeding arising from a dispute hereunder, that the sum of Tenant’s Share of the actual Expense Excess plus Tenant’s Share of the actual Tax Excess is less or more than the amount reported, Tenant
shall receive a credit in the amount of its overpayment against Rent then or next due hereunder, or pay Landlord the amount of its underpayment with the Rent next due hereunder; provided, however, that if this Lease has expired or terminated and
Tenant has vacated the Premises, Landlord shall pay Tenant the amount of its overpayment (less any Rent due), or Tenant shall pay Landlord the amount of its underpayment, within 30 days after such determination, provided further, that if Expenses
and Taxes for any Expense Year in question have been overstated by more than five percent (5%), then to the overpayment credit to which Tenant is entitled pursuant to the foregoing, Tenant shall be entitled to five


  
 8 







 
percent (5%) simple interest on that portion of each monthly payment of Additional Rent for Expenses and Taxes which represents an overpayment by Tenant of Tenant’s Share of the actual
Expense Excess and/or Tenant’s Share of the actual Tax Excess for such period from the date paid by Tenant to and until such overpayment together with all accrued and un-credited interest thereon is either credited against the installments of
Rent next coming due under this Lease, or if at the expiration or sooner termination of this Lease, offset against any amounts owed by Tenant to Landlord and the balance thereof paid to Tenant. 

 

	5	USE; COMPLIANCE WITH LAWS. 

 5.1. Tenant shall not (a) use the Premises for any purpose other than the Permitted Use, or (b) do anything in or about the Premises that violates any of the Rules and Regulations, damages the
reputation of the Project, unreasonably interferes with, injures or annoys other occupants of the Building, or constitutes a nuisance. Tenant, at its expense, shall comply with all Laws relating to (i) the operation of its business at the
Project, (ii) the use, condition, configuration or occupancy of the Premises, or (iii) any Building systems exclusively serving the Premises; provided, however, that nothing in this sentence shall be deemed to require Tenant to make any
change to any Common Area, the Building structure, or any Building system located outside of and not exclusively serving the Premises. Tenant shall have no obligation to remove any hazardous materials existing in the Premises, Building or Project as
of the Commencement Date. If, in order to comply with any such Law, Tenant must obtain or deliver any permit, certificate or other document evidencing such compliance, Tenant shall provide a copy of such document to Landlord promptly after obtaining
or delivering it. If a change to any Common Area, the Building structure, or any Building system located outside of and not exclusively serving the Premises becomes required under Law (or if any such requirement is enforced) as a result of any
Tenant-Insured Improvement (defined in Section 10.2.2), the installation of any trade fixture, or any use of the Premises other than general office use, Tenant, upon demand, shall (x) at Landlord’s option, either make such
change at Tenant’s cost or pay Landlord the actual and reasonable cost of making such change, and (y) pay Landlord a coordination fee equal to five percent (5%) of the cost of such change. As used herein, “Law” means
any existing or future law, ordinance, regulation or requirement of any governmental authority having jurisdiction over the Project or the parties. 
 5.2 Landlord, at its expense (subject to Section 4), shall cause the Base Building and the Common Areas to comply with all Laws (including the Americans with Disabilities Act
(“ADA”)) to the extent that (a) such compliance is necessary for Tenant to use the Premises for general office use in a normal and customary manner and for Tenant’s employees and visitors to have reasonably safe access to
and from the Premises, or (b) Landlord’s failure to cause such compliance would impose liability upon Tenant under Law; provided, however, that Landlord shall not be required to cause such compliance to the extent non-compliance
(x) is triggered by any matter that is Tenant’s responsibility under Section 5.1 or 7.3 or any other provision hereof, or (y) arises under any provision of the ADA other than Title III thereof. Notwithstanding
the foregoing, Landlord may contest any alleged violation in good faith, including by applying for and obtaining a waiver or deferment of compliance, asserting any defense allowed by Law, and appealing any order or judgment to the extent permitted
by Law; provided, however, that after exhausting any rights to contest or appeal, Landlord shall perform any work necessary to comply with any final order or judgment. Notwithstanding the foregoing, Landlord shall not contest any such alleged
violation if, during the period of such contest: (i) Tenant would not have the ability to use the Premises for general office use in a normal and customary manner, or (ii) Tenant’s employees and visitors would not have reasonably safe
access to and from the Premises. 
 5.3 If any suspected asbestos-containing material or other hazardous material is discovered
in the Premises prior to or during the performance of any work to be performed by Landlord or Tenant therein as provided in this Lease, Landlord, at Landlord’s sole cost and expense, without deduction from Tenant’s improvement allowance,
shall retain a licensed and qualified environmental consultant to inspect the suspected asbestos containing material or other hazardous material and, as appropriate in accordance with legal requirements and the recommendation of such consultant,
shall remove, remediate, encapsulate, entomb or leave undisturbed such asbestos-containing material or other hazardous material. All such work shall be coordinated with Tenant in a manner to minimize any delay in performance of any improvements to
such space or the delay in the timely delivery of the space in the required condition or, if Tenant is then in occupancy of the Premises, in a manner to minimize any interruption of Tenant’s use of or access to the Premises. 

 

	6	SERVICES. 

 6.1
Standard Services. Landlord shall provide the following services on all days (unless otherwise stated below): (a) subject to limitations imposed by Law, customary heating, ventilation and air conditioning
(“HVAC”) in season during Building HVAC Hours; (b) electricity supplied by the applicable public utility, stubbed to the Premises; (c) water supplied by the applicable public utility (i) for use in
lavatories and any drinking facilities located in Common Areas within the Building, and (ii) stubbed to the Building core for use in any plumbing fixtures located in the Premises; (d) janitorial services to the Premises, except on weekends
and Holidays, in a manner that is reasonably comparable to other comparable Class A office buildings of similar size and age as the Building located in the same geographic market as the Building (“Comparable
Buildings”). Any janitorial services that are provided 

  
 9 







 
on normal business days shall be performed after 5:00 pm; (e) elevator service (subject to scheduling by Landlord, and payment of Landlord’s standard usage fee, for any freight
service); (f) access to the Building for Tenant and its employees, 24 hours per day/7 days per week, subject to the terms hereof and such security or monitoring systems as Landlord may reasonably impose, including sign-in procedures and/or
presentation of identification cards; and (g) subject to Section 10.1, security to control and monitor access to the Building, consistent with office buildings in the vicinity of the Building of comparable age, size and condition as
the Building, which may be provided through a security system involving one or more cameras, monitoring devices or guards, sign-in or identification procedures or any comparable system. 

6.2 Above-Standard Use. Landlord shall provide HVAC service outside Building HVAC Hours if Tenant gives Landlord such prior
notice and pays Landlord’s then current per hour charge per zone as is in effect from time to time for the Building and applicable to tenants of the Building in general. The rate charged to Tenant and other tenants of the Building in general
for such HVAC service outside Building HVAC Hours shall always be approximately at Landlord’s cost plus a reasonable rate of return to cover Landlord’s overhead and investment in the HVAC system for the Building. Tenant shall not, without
Landlord’s prior consent, use equipment (other than normal office equipment, including computers and servers) that may materially affect the temperature maintained by the air conditioning system or consume above-Building-standard amounts of any
water furnished for the Premises by Landlord pursuant to Section 6.1. If Tenant’s consumption of electricity or water exceeds the rate Landlord reasonably deems to be standard for the Building, Tenant shall pay Landlord, upon
billing, the cost of such excess consumption, including any costs of installing, operating and maintaining any equipment that is installed in order to supply or measure such excess electricity or water. The connected electrical load of Tenant’s
incidental-use equipment shall not exceed the Building-standard electrical design load, and Tenant’s electrical usage shall not exceed the capacity of the feeders to the Project or the risers or wiring installation. For purposes hereof, the
“electrical standard” for the Building is: (i) a design load of 1.5 watts per square foot of net usable floor area for all building standard overhead lighting located within the Premises which requires a
voltage of 480/277 volts; and (ii) a connected load of 2.5 watts per square foot of net usable area for all equipment located and operated within the Premises which requires a voltage of 120/208 volts single phase or less, it being
understood that electricity required to operate the base building HVAC system is not included within or deducted from such 2.5 watts per square foot described in this subsection (ii). In the event that Tenant requires any services or
utilities (other than HVAC) in addition to those services provided by Landlord to all tenants of the Building, Landlord’s charges to Tenant for providing such services shall be equal to the actual costs incurred by Landlord in providing such
services with no additional charge for administrative costs of profit to Landlord. 
 6.3 Interruption. Any
failure to furnish, delay in furnishing, or diminution in the quality or quantity of any service resulting from any application of Law, failure of equipment, performance of maintenance, repairs, improvements or alterations, utility interruption, or
event of Force Majeure (each, a “Service Interruption”) shall not render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. Notwithstanding the foregoing, if
all or a material portion of the Premises is made untenantable or inaccessible for more than five (5) consecutive business days after notice from Tenant to Landlord by a Service Interruption that Landlord can correct through reasonable efforts,
then, as Tenant’s sole remedy, Monthly Rent shall abate for the period beginning on the day immediately following such 5-business-day period and ending on the day such Service Interruption ends (it being agreed that all Service Interruptions
resulting from (i) damage to the Building, (ii) the performance of (or failure to perform) any maintenance, repairs, improvements or alterations by Landlord, or (iii) any other tenants or occupants of the Building are capable of being
corrected by the reasonable efforts of Landlord), but only in proportion to the percentage of the rentable square footage of the Premises made untenantable or inaccessible. 

 

	7	REPAIRS AND ALTERATIONS. 


7.1 Repairs. Subject to Section 11, Tenant, at its expense, shall perform all maintenance and repairs (including
replacements) to the Premises, and keep the Premises in as good condition and repair as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, except for reasonable wear and tear and repairs that are Landlord’s
express responsibility hereunder. Tenant’s maintenance and repair obligations shall include (a) all leasehold improvements in the Premises, whenever and by whomever installed or paid for, including any Tenant Improvements, any Alterations
(defined in Section 7.2), and any leasehold improvements installed pursuant to any prior lease, but excluding the Base Building (the “Leasehold Improvements”); (b) all supplemental heating, ventilation
and air conditioning units, kitchens (including hot water heaters, dishwashers, garbage disposals, insta-hot dispensers, and plumbing) and similar facilities exclusively serving Tenant, whether located inside or outside of the Premises, and whenever
and by whomever installed or paid for; and (c) all Lines (defined in Section 23). Notwithstanding the foregoing, Landlord may, at its option, perform such maintenance and repairs on Tenant’s behalf, in which case Tenant shall
pay Landlord, upon demand, the cost of such work plus a coordination fee equal to five percent (5%) of such cost. Landlord shall perform all maintenance and repairs to (i) the roof and exterior walls and windows of the Building,
(ii) the Base Building, and (iii) the Common Areas. As used herein, “Base Building” means the structural portions of the Building, together with all mechanical (including HVAC), electrical, plumbing and
fire/life-safety 

  
 10 








 
systems serving the Building in general, whether located inside or outside of the Premises. In addition to the foregoing, Landlord shall at all times maintain the Building in a manner consistent
with Comparable Buildings and in compliance with applicable Laws. Landlord shall perform its maintenance and repair obligations in a manner that is reasonably designed to minimize disruption of the operation of the businesses of Tenant and the other
tenants of the Building; provided that the foregoing shall not be construed to require Landlord to perform work before or after normal business hours unless that nature of the work is such that commonly accepted practice in Comparable Buildings
would be to perform such work before or after normal business hours. 
 7.2 Alterations. Tenant may not make any
improvement, alteration, addition or change to the Premises or to any mechanical, plumbing or HVAC facilities or other systems serving the Premises (an “Alteration”) without Landlord’s prior consent, which consent shall be
requested by Tenant not less than 30 days before commencement of work and shall not be unreasonably withheld by Landlord. Notwithstanding the foregoing, provided that Landlord receives 10 business days’ prior notice, Landlord’s
prior consent shall not be required for any Alteration that (i) is reasonably estimated (together with any other Alterations performed without Landlord’s consent pursuant to this sentence during the 12-month period ending on the date of
such notice) to cost less than $40,000.00; (ii) is not visible from outside the Premises; (iii) does not affect any system or structural component of the Building; and (iv) does not require work to be performed inside the walls or
above the ceiling of the Premises. For any Alteration, (a) Tenant, before commencing work, shall deliver to Landlord, and obtain Landlord’s approval of, plans and specifications; (b) Landlord, in its reasonable discretion, may require
Tenant to obtain security for performance reasonably satisfactory to Landlord; (c) Tenant shall deliver to Landlord “as built” drawings (in CAD format, if reasonably requested by Landlord), completion affidavits, full and final lien
waivers, and all governmental approvals; and (d) Tenant shall pay Landlord upon demand (i) Landlord’s reasonable out-of-pocket expenses incurred in reviewing the work, and (ii) a coordination fee equal to five percent
(5%) of the cost of the work; provided, however, that this clause (d) shall not apply to any Tenant Improvements constructed pursuant to Exhibit B. 
 7.3 Tenant Work. Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and, if Landlord’s prior written approval is required for
such Tenant Work as provided in Section 7.2 above, obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’
insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality, and if Landlord’s approval is required for such work as provided in
Section 7.2 above, reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a
manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall
comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this
Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in
performing other work or services at the Project. 
 8    LANDLORD’S PROPERTY. All Leasehold Improvements shall
become Landlord’s property upon installation and without compensation to Tenant. Notwithstanding the foregoing, if any Tenant-Insured Improvements are not, in Landlord’s reasonable judgment, Building-standard, then before the expiration or
earlier termination hereof, Tenant shall, at Landlord’s election, either (a) at Tenant’s expense, and except as otherwise notified by Landlord, remove such Tenant-Insured Improvements, repair any resulting damage to the Premises or
Building, and restore the affected portion of the Premises to its condition existing before the installation of such Tenant-Insured Improvements (or, at Landlord’s election, to a Building-standard tenant-improved condition as determined by
Landlord), or (b) pay Landlord an amount equal to the estimated cost of such work, as reasonably determined by Landlord. If Tenant fails to timely perform any work required under clause (a) of the preceding sentence, Landlord may perform
such work at Tenant’s expense. Notwithstanding the foregoing, except for Lines (defined in Section 23), Landlord shall not require Tenant to remove any Tenant Improvements or Alterations unless Landlord, at the time that it granted
approval for such Tenant Improvements or Alterations, advised Tenant in writing that removal would be required by Tenant at the end of the Term. 
 9     LIENS. Tenant shall keep the Project free from any lien arising out of any work performed, material furnished or obligation incurred by or on behalf of Tenant. Tenant
shall remove any such lien within 10 business days after notice from Landlord, and if Tenant fails to do so, Landlord, without limiting its remedies, may pay the amount necessary to cause such removal, whether or not such lien is valid. The amount
so paid, together with reasonable attorneys’ fees and expenses, shall be reimbursed by Tenant upon demand. Notwithstanding the foregoing, in lieu of removing such lien, Tenant, upon prior written notice to Landlord, at Tenant’s expense,
may contest, by appropriate legal proceedings conducted in good faith and with due diligence, the amount, validity or application, in whole or in part, of any such lien; subject, however, to the further requirement that (a) the commencement and
continuation of such proceedings shall suspend the collection thereof from Landlord and the Project; (b) neither the Project, the 

  
 11 








 
rent or income therefrom nor any part or interest in either thereof would be in any danger of being sold, forfeited, attached or lost pending the outcome of such proceedings; and (c) Tenant
shall give such reasonable security as may be required by Landlord to insure ultimate payment of the same and to prevent any sale or forfeiture of the Project, the rent or income therefrom or any part or interest in either by reason of such
nonpayment. If any such contest is finally resolved against Tenant, Tenant shall promptly pay the amount required to be paid, together with all interest and penalties accrued thereon. Tenant shall indemnify, defend, protect and save Landlord
harmless from and against any liability, cost or expense of any kind that may be imposed upon Landlord in connection with any such contest and any loss resulting therefrom. 

 

	10	INDEMNIFICATION; INSURANCE. 

 10.1 Waiver and Indemnification. Tenant waives all claims against Landlord, its Security Holders (defined in Section 17), Landlord’s managing agent(s), their (direct or
indirect) owners, and the beneficiaries, trustees, officers, directors, employees and agents of each of the foregoing (including Landlord, the “Landlord Parties”) for (i) any damage to person or property (or resulting from the
loss of use thereof), except to the extent such damage is caused by the negligence or willful misconduct of any Landlord Party, or (ii) any failure to prevent or control any criminal or otherwise wrongful conduct by any third party or to
apprehend any third party who has engaged in such conduct. Tenant shall indemnify, defend, protect, and hold the Landlord Parties harmless from any obligation, loss, claim, action, liability, penalty, damage, cost or expense (including reasonable
attorneys’ and consultants’ fees and expenses) (each, a “Claim”) that is imposed or asserted by any third party and arises from (a) any cause in, on or about the Premises, (b) occupancy of the Premises by, or any
negligence or willful misconduct of, Tenant, any party claiming by, through or under Tenant, their (direct or indirect) owners, or any of their respective beneficiaries, trustees, officers, directors, employees, agents, contractors, licensees or
invitees, or (c) any breach by Tenant of any representation, covenant or other term contained herein, except to the extent such Claim arises from the negligence or willful misconduct of any Landlord Party. Landlord shall indemnify, defend,
protect, and hold Tenant, its (direct or indirect) owners, and their respective beneficiaries, trustees, officers, directors, employees and agents (including Tenant, the “Tenant Parties”) harmless from any Claim that is imposed or
asserted by any third party and arises from (a) any negligence or willful misconduct of any Landlord Party, or (b) any breach by Landlord of any representation, covenant or other term contained herein, except to the extent such Claim
arises from the negligence or willful misconduct of any Tenant Party. 
 10.2 Tenant’s Insurance. Tenant
shall maintain the following coverages in the following amounts: 
 10.2.1 Commercial General Liability Insurance covering
claims of bodily injury, personal injury and property damage arising out of Tenant’s operations and contractual liabilities, including coverage formerly known as broad form, on an occurrence basis, with minimum primary limits of $1,000,000 each
occurrence and $2,000,000 annual aggregate (and not more than $25,000 self-insured retention) and a minimum excess/umbrella limit of $2,000,000. 
 10.2.2 Property Insurance covering (i) all office furniture, trade fixtures, office equipment, free-standing cabinet work, movable partitions, merchandise and all other items of Tenant’s
property in the Premises installed by, for, or at the expense of Tenant, and (ii) any Leasehold Improvements installed by or for the benefit of Tenant, whether pursuant to this Lease or pursuant to any prior lease or other agreement to which
Tenant was a party (“Tenant-Insured Improvements”). Such insurance shall be written on a special cause of loss form for physical loss or damage, for the full replacement cost value (subject to reasonable deductible amounts) new
without deduction for depreciation of the covered items and in amounts that meet any co-insurance clauses of the policies of insurance, and shall include coverage for damage or other loss caused by fire or other peril, including vandalism and
malicious mischief, theft, water damage of any type, including sprinkler leakage, bursting or stoppage of pipes, and explosion, and providing business interruption coverage for a period of one year. 

10.2.3 Worker’s Compensation and Employer’s Liability or other similar insurance to the extent required by Law. 

10.3 Form of Policies. The minimum limits of insurance required to be carried by Tenant shall not limit Tenant’s
liability. Such insurance shall be issued by an insurance company that has an A.M. Best rating of not less than A-VIII and shall be in form and content reasonably acceptable to Landlord. Tenant’s Commercial General Liability Insurance
shall (a) name the Landlord, Landlord’s property manager and any other party designated in writing by Landlord as having an insurable interest in the Property (“Additional Insured Parties”) as additional insureds; and
(b) be primary insurance as to all claims thereunder and provide that any insurance carried by Landlord is excess and non-contributing with Tenant’s insurance. Landlord shall be designated as a loss payee with respect to Tenant’s
Property Insurance on any Tenant-Insured Improvements and trade fixtures. Tenant shall deliver to Landlord, on or before the Commencement Date and at least 15 days before the expiration dates thereof, certificates from Tenant’s insurance
company on the forms currently designated “ACORD 25-S” (Certificate of Liability Insurance) and “ACORD 28” (Evidence of Commercial Property Insurance) or the equivalent. 

  
 12 








 
Attached to the ACORD 25-S (or equivalent) there shall be an endorsement naming the Additional Insured Parties as additional insureds, and attached to the ACORD 28 (or equivalent) there
shall be an endorsement designating Landlord as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements and trade fixtures, and each such endorsement shall be binding on Tenant’s insurance company. Upon
Landlord’s request, Tenant shall deliver to Landlord, in lieu of such certificates, copies of the policies of insurance required to be carried under Section 10.2 showing that the Additional Insured Parties are named as additional
insureds and that Landlord is designated as a loss payee with respect to Tenant’s Property Insurance on any Tenant-Insured Improvements and trade fixtures. 
 10.4 Subrogation. Each party waives, and shall cause its insurance carrier to waive, any right of recovery against the other party, any of its (direct or indirect) owners, or any of their
respective beneficiaries, trustees, officers, directors, employees or agents for any loss of or damage to property which loss or damage is (or, if the insurance required hereunder had been carried, would have been) covered by property insurance. For
purposes of this Section 10.4 only, (a) any deductible with respect to a party’s insurance shall be deemed covered by, and recoverable by such party under, valid and collectable policies of insurance, and (b) any
contractor retained by Landlord to install, maintain or monitor a fire or security alarm for the Building shall be deemed an agent of Landlord. 
 10.5 Additional Insurance Obligations. Tenant shall maintain such increased amounts of the insurance required to be carried by Tenant under this Section 10, and such other types
and amounts of insurance covering the Premises and Tenant’s operations therein, as may be reasonably requested by Landlord, but not in excess of the amounts and types of insurance then being required by landlords of buildings comparable to and
in the vicinity of the Building. 
 10.6 Landlord’s Insurance. Landlord shall maintain the following
insurance, together with such other insurance coverage as Landlord, in its reasonable judgment, may elect to maintain, the premiums of which shall be included in Expenses: (a) Commercial General Liability insurance applicable to the Property,
Building and Common Areas providing, on an occurrence basis, a minimum combined single limit of at least $3,000,000.00; (b) Special Cause of Loss Insurance on the Building at replacement cost value as reasonably estimated by Landlord;
(c) Worker’s Compensation insurance to the extent required by Law; and (d) Employers Liability Coverage to the extent required by Law. 
 11     CASUALTY DAMAGE. With reasonable promptness after discovering any damage to the Premises, or to the Common Areas necessary for access to and/or use of the Premises,
resulting from any fire or other casualty (a “Casualty”), Landlord shall notify Tenant of Landlord’s reasonable estimate of the time required to substantially complete repair of such damage (the “Landlord
Repairs”). If, according to such estimate, the Landlord Repairs cannot be substantially completed within 270 days after they are commenced, either party may terminate this Lease upon 60 days’ notice to the other party
delivered within 10 days after Landlord’s delivery of such estimate. Within 90 days after discovering any damage to the Building or Project resulting from any Casualty, Landlord may, whether or not the Premises is affected, terminate
this Lease by notifying Tenant if (i) any Security Holder terminates any ground lease or requires that any insurance proceeds be used to pay any mortgage debt; (ii) any damage to Landlord’s property is not fully covered by
Landlord’s insurance policies; (iii) Landlord decides to rebuild the Building or Common Areas so that it or they will be substantially different structurally or architecturally; (iv) the damage occurs during the last 12 months of
the Term; or (v) any owner, other than Landlord, of any damaged portion of the Project does not intend to repair such damage; provided, however, that Landlord may not terminate this Lease pursuant to this sentence unless the Premises has been
materially damaged or Landlord also exercises all rights it may have acquired as a result of the Casualty to terminate any other similarly situated leases of space in the Building. Tenant may terminate this Lease, by notice to Landlord within
30 days after receiving Landlord’s estimate of the time required to substantially complete the Landlord Repairs, if (a) the Casualty has occurred during the last 12 months of the Term and has damaged a material portion of the
Premises, and (b) such estimate indicates that the damage cannot reasonably be repaired within 60 days after Tenant’s receipt of such estimate. If this Lease is not terminated pursuant to this Section 11, Landlord shall
promptly and diligently perform the Landlord Repairs, subject to reasonable delays for insurance adjustment and other events of Force Majeure. The Landlord Repairs shall restore the Premises (including any Tenant-Insured Improvements and trade
fixtures) and the Common Areas necessary for access to the Premises to substantially the same condition that existed when the Casualty occurred, except for (a) any modifications required by Law or any Security Holder, and (b) any
modifications to the Common Areas that are deemed desirable by Landlord, are consistent with the character of the Project, and do not materially impair access to or use of the Premises. Notwithstanding Section 10.4, Tenant shall assign
to Landlord (or its designee) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.2 with respect to any Tenant-Insured Improvements and trade fixtures, and if the estimated or actual cost of
restoring any Tenant-Insured Improvements and trade fixtures exceeds the insurance proceeds received by Landlord from Tenant’s insurance carrier, Tenant shall pay such excess to Landlord within 15 days after Landlord’s demand. No
Casualty and no restoration performed as required hereunder shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder; provided, however, that if the Premises or any Common Area
necessary for Tenant’s access to or use of the Premises is damaged by a Casualty, then, during any time that, as a result of such damage, 

  
 13 








 
any portion of the Premises is untenantable or inaccessible and is not used and occupied by Tenant for the conduct of business, Monthly Rent shall be abated in proportion to the rentable square
footage of such portion of the Premises. 
 12     NONWAIVER. No provision hereof shall be deemed waived by either
party unless it is waived by such party expressly and in writing, and no waiver of any breach of any provision hereof shall be deemed a waiver of any subsequent breach of such provision or any other provision hereof. Landlord’s acceptance of
Rent shall not be deemed a waiver of any preceding breach of any provision hereof, other than Tenant’s failure to pay the particular Rent so accepted, regardless of Landlord’s knowledge of such preceding breach at the time of such
acceptance. No acceptance of payment of an amount less than the Rent due hereunder shall be deemed a waiver of Landlord’s right to receive the full amount of Rent due, whether or not any endorsement or statement accompanying such payment
purports to effect an accord and satisfaction. No receipt of monies by Landlord from Tenant after the giving of any notice, the commencement of any suit, the issuance of any final judgment, or the termination hereof shall affect such notice, suit or
judgment, or reinstate or extend the Term or Tenant’s right of possession hereunder. 
 13     CONDEMNATION. If
any part of the Premises, Building or Project is taken for any public or quasi-public use by power of eminent domain or by private purchase in lieu thereof (a “Taking”) for more than 180 consecutive days, Landlord may terminate
this Lease. Notwithstanding the foregoing, with respect to any Taking which does not include a portion of the Premises, Landlord shall not terminate this Lease in accordance with the immediately preceding sentence unless Landlord also terminates the
leases of similarly affected tenants in the Building for whom Landlord has the right to terminate. If more than 25% of the rentable square footage of the Premises is Taken, or access to or use of the Premises is substantially impaired as a result of
a Taking, for more than 180 consecutive days, Tenant may terminate this Lease. Any such termination shall be effective as of the date possession must be surrendered to the authority, and the terminating party shall provide termination notice to
the other party within 45 days after receiving written notice of such surrender date. Except as provided above in this Section 13, neither party may terminate this Lease as a result of a Taking. Tenant shall not assert any claim for
compensation because of any Taking; provided, however, that Tenant may file a separate claim for any Taking of Tenant’s personal property or any fixtures that Tenant is entitled to remove upon the expiration hereof, and for moving expenses, so
long as such claim does not diminish the award available to Landlord or any Security Holder and is payable separately to Tenant. If this Lease is terminated pursuant to this Section 13, all Rent shall be apportioned as of the date of
such termination. If a Taking occurs and this Lease is not so terminated, Monthly Rent shall be abated for the period of such Taking in proportion to the percentage of the rentable square footage of the Premises, if any, that is subject to, or
rendered inaccessible or untenantable by, such Taking. 
  

	14	ASSIGNMENT AND SUBLETTING. 


14.1 Transfers. Except for a Permitted Transfer as hereinafter provided, Tenant shall not, without Landlord’s prior
consent, assign, mortgage, pledge, hypothecate, encumber, permit any lien to attach to, or otherwise transfer this Lease or any interest hereunder, permit any assignment or other transfer hereof or any interest hereunder by operation of law, enter
into any sublease or license agreement, otherwise permit the occupancy or use of any part of the Premises by any persons other than Tenant and its employees and contractors, or permit a Change of Control (defined in Section 14.6) to
occur (each, a “Transfer”). If Tenant desires Landlord’s consent to any Transfer, Tenant shall provide Landlord with (i) notice of the terms of the proposed Transfer, including its proposed effective date (the
“Contemplated Effective Date”), a description of the portion of the Premises to be transferred (the “Contemplated Transfer Space”), a calculation of the Transfer Premium (defined in Section 14.3), and a
copy of all existing executed and/or proposed documentation pertaining to the proposed Transfer, and (ii) current financial statements of the proposed transferee (or, in the case of a Change of Control, of the proposed new controlling
party(ies)) certified by an officer or owner thereof and any other information reasonably required by Landlord in order to evaluate the proposed Transfer (collectively, the “Transfer Notice”). Within 30 days after receiving the
Transfer Notice, Landlord shall notify Tenant of (a) its consent to the proposed Transfer, (b) its refusal to consent to the proposed Transfer, and stating with reasonable specificity the reasons therefor, or (c) its exercise of its
rights under Section 14.4. Except for a Permitted Transfer, any Transfer made without Landlord’s prior consent shall, at Landlord’s option, be void and shall, at Landlord’s option, constitute a Default (defined in
Section 19). Tenant shall pay Landlord a fee of $1,500.00 for Landlord’s review of any proposed Transfer, whether or not Landlord consents to it. 
 14.2 Landlord’s Consent. Subject to Section 14.4, Landlord shall not unreasonably withhold its consent to any proposed Transfer. Without limiting other reasonable grounds
for withholding consent, it shall be deemed reasonable for Landlord to withhold consent to a proposed Transfer if: 
 14.2.1 The
proposed transferee is not a party of reasonable financial strength in light of the responsibilities to be undertaken in connection with the Transfer on the date the Transfer Notice is received; or 

14.2.2 The proposed transferee has a character or reputation or is engaged in a business that is not consistent with the quality of the
Building or the Project; or 

  
 14 








 14.2.3 The proposed transferee is a governmental entity or a nonprofit organization; or

 14.2.4 INTENTIONALLY OMITTED; or 
 14.2.5 The proposed transferee or any of its Affiliates, on the date the Transfer Notice is received, leases or occupies (or, at any time during the 6-month period ending on the date the Transfer Notice
is received, has negotiated with Landlord to lease) space in the Project. 
 Notwithstanding any contrary provision hereof,
(a) if Landlord consents to any Transfer pursuant to this Section 14.2 but Tenant does not enter into such Transfer within six (6) months thereafter, such consent shall no longer apply and such Transfer shall not be permitted
unless Tenant again obtains Landlord’s consent thereto pursuant and subject to the terms of this Section 14; and (b) if Landlord unreasonably withholds its consent under this Section 14.2, Tenant’s sole
remedies shall be contract damages (subject to Section 20) or specific performance, and Tenant waives all other remedies, including any right to terminate this Lease. 

14.3 Transfer Premium. Except with respect to a Change of Control, a Permitted Transfer or any other Transfer not requiring
Landlord’s prior written consent, if Landlord consents to a Transfer, Tenant shall pay Landlord an amount equal to 50% of any Transfer Premium (defined below). As used herein, “Transfer Premium” means (a) in the case of an
assignment, any consideration (including payment for Leasehold Improvements) paid by the assignee for such assignment, less any reasonable and customary expenses directly incurred by Tenant on account of such assignment, including brokerage fees,
legal fees, and Landlord’s review fee; or (b) in the case of a sublease, license or other occupancy agreement, the amount by which all rent and other consideration paid by the transferee to Tenant pursuant to such agreement (less all
reasonable and customary expenses directly incurred by Tenant on account of such agreement, including brokerage fees, legal fees, construction costs and Landlord’s review fee) exceeds the Monthly Rent payable by Tenant hereunder with respect to
the Contemplated Transfer Space for the term of such agreement. Payment of Landlord’s share of the Transfer Premium shall be made (x) in the case of an assignment, within 10 days after Tenant or the prior controlling party(ies), as the
case may be, receive(s) the consideration described above, and (y) in the case of a sublease, license or other occupancy agreement, on the first day of each month during the term of such agreement, in the amount of 50% of the amount by which
the rent and other consideration paid by the transferee to Tenant under such agreement for such month (less all reasonable and customary expenses directly incurred by Tenant on account of such agreement, including brokerage fees, legal fees,
construction costs and Landlord’s review fee, as amortized on a monthly, straight-line basis over the term of such agreement) exceeds the Monthly Rent payable by Tenant hereunder with respect to the Contemplated Transfer Space for such month.

 14.4 Landlord’s Right to Recapture. Notwithstanding any contrary provision hereof, except in the case of a
Permitted Transfer (defined in Section 14.8), Landlord, by notifying Tenant within 30 days after receiving the Transfer Notice, may terminate this Lease with respect to the Contemplated Transfer Space as of the Contemplated
Effective Date; provided, however, that such termination shall not be effective if Tenant, by notifying Landlord within five (5) days after receiving Landlord’s notice of termination, withdraws the Transfer Notice. If Tenant does not
timely withdraw the Transfer Notice, and if the Contemplated Transfer Space is less than the entire Premises, then Base Rent, Tenant’s Share, and the number of parking spaces to which Tenant is entitled under Section 1.9 shall be
deemed adjusted on the basis of the percentage of the rentable square footage of the Premises retained by Tenant. Upon request of either party, the parties shall execute a written agreement prepared by Landlord memorializing such termination.

 14.5 Effect of Consent. If Landlord consents to a Transfer, (i) such consent shall not be deemed a consent
to any further Transfer, (ii) Tenant shall deliver to Landlord, promptly after execution, an executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord, and (iii) Tenant shall deliver to
Landlord, upon Landlord’s request, a complete statement, certified by an independent CPA or Tenant’s chief financial officer, setting forth in detail the computation of any Transfer Premium. In the case of an assignment, the assignee shall
assume in writing, for Landlord’s benefit, all of Tenant’s obligations hereunder. No Transfer, with or without Landlord’s consent, shall relieve Tenant or any guarantor hereof from any liability hereunder. Notwithstanding any contrary
provision hereof, Tenant, with or without Landlord’s consent, shall not enter into, or permit any party claiming by, through or under Tenant to enter into, any sublease, license or other occupancy agreement that provides for payment based in
whole or in part on the net income or profit of the subtenant, licensee or other occupant thereunder. 
 14.6 Change of
Control. As used herein, “Change of Control” means (a) if Tenant is a closely held professional service firm, the withdrawal or change (whether voluntary, involuntary or by operation of law) of 50% or more of its
equity owners within a 12-month period; and (b) in all other cases, any transaction(s) resulting in the acquisition of a Controlling Interest (defined below) by one or more parties that did not own a Controlling Interest immediately before such
transaction(s). As used herein, “Controlling Interest” means any direct or indirect equity or beneficial ownership interest in Tenant that confers upon its holder(s) the direct or indirect power to direct the ordinary management and
policies of Tenant, whether through the ownership of voting securities, by contract or otherwise (but not through the 

  
 15 








 
ownership of voting securities (i) listed on any recognized securities exchange or authorized for quotation on a recognized market or other comparable trading system or (ii) traded over
any over-the-counter market, including, without limitation, the OTCBB, the OTC QX or the Pink Sheets). Notwithstanding the foregoing, a Change of Control shall not be deemed to have occurred for purposes of this Article 14 so long as Alan H.
Auerbach remains the Chief Executive Officer of Tenant following such transaction(s), and the tangible net worth of the Tenant after the transaction is the same or better than the tangible net worth immediately prior to the exchange. 

14.7 Effect of Default. If Tenant is in Default, Landlord is irrevocably authorized, as Tenant’s agent and
attorney-in-fact, to direct any transferee under any sublease, license or other occupancy agreement to make all payments under such agreement directly to Landlord (which Landlord shall apply towards Tenant’s obligations hereunder) until such
Default is cured. Such transferee shall rely upon any representation by Landlord that Tenant is in Default, whether or not confirmed by Tenant. 
 14.8 Permitted Transfers. Notwithstanding any contrary provision hereof, each of the following shall be permitted without the Landlord’s prior written consent, without the payment of
any Transfer Premium pursuant to Section 14.3 (each, a “Permitted Transfer”): 
 14.8.1 The transfer of
securities of Tenant among the members of the immediate family of a security holder, to a living trust for estate planning purposes or by will or intestacy, to existing shareholders of Tenant or to Tenant; 

14.8.2 Any transfer or issuance of securities of Tenant to an institutional or other investor (herein, an “Investor”),
so long as in connection therewith Alan H. Auerbach remains the Chief Executive Officer of Tenant; 
 14.8.3 Any transfer or
issuance of securities of any Investor, regardless of whether such transfer results in a Change of Control of such Investor; 

14.8.4 A sale, issuance or transfer of securities of Tenant to the public or public trading of the securities of Tenant (A) listed
on any recognized securities exchange or authorized for quotation on a recognized market or other comparable trading system or (B) traded over any over-the-counter market, including, without limitation, the OTCBB, the OTC QX or the Pink
Sheets); 
 14.8.5 If Tenant is not in Default, (a) an assignment of this Lease or subletting or licensing of all or any
portion of the Premises to an Affiliate of Tenant, (b) an assignment of this Lease or subletting of all of the Premises as an entirety to (i) any surviving entity in any merger, consolidation or reorganization to which Tenant or its parent
is a party, or (ii) to any entity which acquires all or substantially all of the outstanding capital securities or assets of Tenant or its parent, provided that (i) at least 10 business days before any such Transfer, Tenant notifies
Landlord of such Transfer and delivers to Landlord any documents or information reasonably requested by Landlord relating thereto, including reasonable documentation that the Transfer satisfies the requirements of this Section 14.8.5;
(ii) in the case of an assignment pursuant to clause (a) or ( b) above (other than a where the surviving entity assumes the obligations of the Tenant hereunder by operation of law (e.g., a merger)), the assignee executes and delivers to
Landlord, at least 10 business days before the assignment, a commercially reasonable instrument pursuant to which the assignee assumes, for Landlord’s benefit, all of Tenant’s obligations hereunder; (iii) in the case of an assignment
pursuant to clause (b) above, (A) the surviving entity has a net worth (as determined in accordance with GAAP, but excluding intellectual property and any other intangible assets (“Net Worth”)) immediately after the
Transfer that is not less than the Net Worth of Tenant immediately before the Transfer, and (B) if Tenant is a closely held professional service firm, at least 75% of its equity owners existing 12 months before the Transfer are also equity
owners of the successor entity; (iv) in the case of an assignment pursuant to either clause (a) or (b), the transferee is qualified to conduct business in the State of California; and (v) the Transfer is made for a good faith
operating business purpose and not in order to evade the requirements of this Section 14. As used herein, “Affiliate” means, with respect to any party, a person or entity that controls, is under common control with, or is controlled
by such party. 
 15     SURRENDER. Upon the expiration or earlier termination hereof, and subject to
Sections 8 and 11 and this Section 15, Tenant shall surrender possession of the Premises to Landlord in as good condition and repair as when Tenant took possession and as thereafter improved by Landlord and/or Tenant,
except for reasonable wear and tear, damage by Casualty and repairs that are Landlord’s express responsibility hereunder. Before such expiration or termination, Tenant, without expense to Landlord, shall (a) remove from the Premises all
debris and rubbish and all furniture, equipment, trade fixtures, Lines, free-standing cabinet work, movable partitions and other articles of personal property that are owned or placed in the Premises by Tenant or any party claiming by, through or
under Tenant (except for any Lines not required to be removed under Section 23), and (b) repair all damage to the Premises and Building resulting from such removal. If Tenant fails to timely perform such removal and repair, Landlord
may do so at Tenant’s expense (including storage costs). If Tenant fails to remove such property from the Premises, or from 

  
 16 








 
storage, within 30 days after notice from Landlord, any part of such property shall be deemed, at Landlord’s option, either (x) conveyed to Landlord without compensation, or
(y) abandoned. 
 16     HOLDOVER. If Tenant fails to surrender the Premises upon the expiration or earlier
termination hereof, Tenant’s tenancy shall be subject to the terms and conditions hereof; provided, however, that such tenancy shall be a tenancy at sufferance only, for the entire Premises, and Tenant shall pay Monthly Rent (on a per-month
basis without reduction for any partial month) at a rate equal to 150% of the Monthly Rent applicable during the last calendar month of the Term. Nothing in this Section 16 shall limit Landlord’s rights or remedies or be deemed a
consent to any holdover. If Landlord is unable to deliver possession of the Premises to a new tenant or to perform improvements for a new tenant as a result of Tenant’s holdover, Tenant shall be liable for all resulting damages, including lost
profits, incurred by Landlord. 
 17     SUBORDINATION; ESTOPPEL CERTIFICATES. 

17.1 Except as set forth in Section 17.2 to the contrary, this Lease shall be subject and subordinate to all existing and future
ground or underlying leases, mortgages, trust deeds and other encumbrances against the Building or Project, all renewals, extensions, modifications, consolidations and replacements thereof (each, a “Security Agreement”), and all
advances made upon the security of such mortgages or trust deeds, unless in each case the holder of such Security Agreement (each, a “Security Holder”) requires in writing that this Lease be superior thereto. Upon any termination or
foreclosure (or any delivery of a deed in lieu of foreclosure) of any Security Agreement, Tenant, upon request, shall attorn, without deduction or set-off, to the Security Holder or purchaser or any successor thereto and shall recognize such party
as the lessor hereunder provided that such party agrees not to disturb Tenant’s occupancy so long as Tenant timely pays the Rent and otherwise performs its obligations hereunder. Within 10 days after request by Landlord, Tenant shall
execute such further instruments as Landlord may reasonably deem necessary to evidence the subordination or superiority of this Lease to any Security Agreement. Tenant waives any right it may have under Law to terminate or otherwise adversely affect
this Lease or Tenant’s obligations hereunder upon a foreclosure. Within 10 business days after Landlord’s request, Tenant shall execute and deliver to Landlord a commercially reasonable estoppel certificate in favor of such parties as
Landlord may reasonably designate, including current and prospective Security Holders and prospective purchasers, provided that, except in the case of a proposed sale or transfer of the Building and/or land thereunder, Landlord shall not request
from Tenant such estoppel certificate more than twice in any calendar year. Within 10 business days after Tenant’s request, Landlord shall execute and deliver to Tenant a commercially reasonable estoppel certificate in favor of such parties as
Tenant may reasonably designate, including current and prospective assignee’s of Tenant’s interest under this Lease, provided that Tenant shall not request from Tenant such estoppel certificate more than twice in any calendar year.
Notwithstanding the foregoing, Landlord will use commercially reasonable efforts to obtain a non-disturbance, subordination and attornment agreement from Landlord’s current Mortgagee (as hereinafter defined) on such Mortgagee’s current
standard form of agreement. “Commercially reasonable efforts” of Landlord shall not require Landlord to incur any cost, expense or liability to obtain such agreement, it being agreed that Tenant shall be responsible for any fee or review
costs charged by the Mortgagee. Commercially reasonable efforts shall, however, require Landlord to: (i) provide Mortgagee with a request to provide Tenant with a SNDA in accordance with the terms of Landlord’s Security Agreement with the
Mortgagee; (ii) promptly provide the Mortgagee with such back-up documentation and other information as the Mortgagee shall request, including, without limitation, a summary of the terms of this Lease, Tenant financial information, and a
relevant market information; (iii) periodically follow-up with Mortgagee about the status of Mortgagee’s approval of the SNDA; and (iv) if Mortgagee refuses to enter into an SNDA, inquire as to the reasons for such disapproval. As
used herein, the term “Mortgagee” shall mean the holder of a mortgage or deed of trust recorded against the Property as of the date hereof. Tenant will, subject to commercially reasonable modifications requested by Tenant, execute the
Mortgagee’s form of non-disturbance, subordination and attornment agreement and return the same to Landlord for execution by the Mortgagee. Landlord’s failure to obtain a non-disturbance, subordination and attornment agreement for Tenant
shall have no effect on the rights, obligations and liabilities of Landlord and Tenant or be considered to be a default by Landlord hereunder. 
 17.2 Notwithstanding Section 17.1, Tenant’s agreement to subordinate this Lease to a future Security Agreement shall not be effective unless Landlord has provided Tenant with a commercially
reasonable non-disturbance agreement from the Security Holder. For purposes of the preceding sentence, a non-disturbance agreement shall not be deemed commercially reasonable unless it provides that: (a) so long as no Default exists, this Lease
and Tenant’s right to possession hereunder shall remain in full force and effect; (b) the Security Holder shall have additional time (not to exceed 90 days after written notice from Tenant) to cure any default of Landlord; and
(c) neither the Security Holder nor any successor in interest shall be (i) bound by (A) any payment of Rent for more than one (1) month in advance, or (B) any amendment of this Lease made without the written consent of the
Security Holder or such successor in interest; (ii) liable for any act, omission, representation, warranty or default of any prior landlord (including Landlord); or (iii) subject to any offset or defense that Tenant might have against
any prior landlord (including Landlord). 

  
 17 








 18     ENTRY BY LANDLORD. At all reasonable times and upon reasonable notice to
Tenant, or in an emergency, Landlord may enter the Premises to (i) inspect the Premises; (ii) show the Premises to prospective purchasers, current or prospective Security Holders or insurers, or, during the last 12 months of the Term (or
while an uncured Default exists), prospective tenants; (iii) post notices of non-responsibility; or (iv) perform maintenance, repairs or alterations. At any time and without notice to Tenant, Landlord may enter the Premises to perform
required services. If reasonably necessary, Landlord may temporarily close any portion of the Premises to perform maintenance, repairs or alterations. In an emergency, Landlord may use any means it deems proper to open doors to and in the Premises.
No entry into or closure of any portion of the Premises pursuant to this Section 18 shall render Landlord liable to Tenant, constitute a constructive eviction, or excuse Tenant from any obligation hereunder. As used herein, an
“emergency” shall be any circumstances or set of facts posing an imminent threat of injury to or death of persons or damage to property. All entries by Landlord and all notices and other items placed in the Premises by Landlord shall, to
the extent possible under the circumstances, be conducted in a manner which causes the least practicable interference with the operation of Tenant’s business in the Premises. 
 19     DEFAULTS; REMEDIES. 
 19.1 Events of
Default. The occurrence of any of the following shall constitute a “Default”: 
 19.1.1 Any failure by
Tenant to pay any Rent when due unless such failure is cured within five (5) business days after notice; or 
 19.1.2
Except where a specific time period is otherwise set forth for Tenant’s performance herein (in which event the failure to perform by Tenant within such time period shall be a Default), and except as otherwise provided in this
Section 19.1, any failure by Tenant to observe or perform any other provision, covenant or condition hereof where such failure continues for 30 days after notice from Landlord; provided that if such failure cannot reasonably be
cured within such 30-day period, Tenant shall not be in Default as a result of such failure if Tenant diligently commences such cure within such period, thereafter diligently pursues such cure to completion; or 

19.1.3 INTENTIONALLY OMITTED; or 
 19.1.4 Any failure by Tenant to observe or perform the provisions of Sections 14, or 17 where such failure continues for more than five (5) business days after notice from
Landlord; or 
 19.1.5 Tenant becomes in breach of Section 25.3 where such failure continues for more than five
(5) business days after notice from Landlord. 
 If Tenant breaches a particular provision hereof (other than a provision
requiring payment of Rent) on three (3) separate occasions during any 12-month period, Tenant’s subsequent breach of such provision shall be, at Landlord’s option, an incurable Default. The notice periods provided herein are in lieu
of, and not in addition to, any notice periods provided by Law, and Landlord shall not be required to give any additional notice in order to be entitled to commence an unlawful detainer proceeding. 

19.2 Remedies Upon Default. Upon any Default, Landlord shall have, in addition to any other remedies available to Landlord
at law or in equity (which shall be cumulative and nonexclusive), the option to pursue any one or more of the following remedies (which shall be cumulative and nonexclusive) without any notice or demand: 

19.2.1 Landlord may terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails
to do so, Landlord may, without prejudice to any other remedy it may have for possession or arrearages in Rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any
part thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following: 
 (a) The worth at the time of award of the unpaid Rent which has been earned at the time of such termination; plus 
 (b) The worth at the time of award of the amount by which the unpaid Rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves
could have been reasonably avoided; plus 
 (c) The worth at the time of award of the amount by which the unpaid Rent for the
balance of the Term after the time of award exceeds the amount of such Rent loss that Tenant proves could have been reasonably avoided; plus 
 (d) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations hereunder or which in the ordinary


  
 18 








 
course of things would be likely to result therefrom, including brokerage commissions, advertising expenses, expenses of remodeling any portion of the Premises for a new tenant (whether for the
same or a different use), and any special concessions made to obtain a new tenant; plus 
 (e) At Landlord’s option, such
other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by Law. 
 As used in
Sections 19.2.1(a) and (b), the “worth at the time of award” shall be computed by allowing interest at a rate per annum equal to the lesser of (i) the annual “Bank Prime Loan” rate cited in the
Federal Reserve Statistical Release Publication G.13(415), published on the first Tuesday of each calendar month (or such other comparable index as Landlord shall reasonably designate if such rate ceases to be published) plus two (2) percentage
points, or (ii) the highest rate permitted by Law. As used in Section 19.2.1(c), the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San
Francisco at the time of award plus 1%. 
 19.2.2 Landlord shall have the remedy described in California Civil Code
§ 1951.4 (lessor may continue lease in effect after lessee’s breach and abandonment and recover Rent as it becomes due, if lessee has the right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord
does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.

 19.2.3 Landlord shall at all times have the rights and remedies (which shall be cumulative with each other and cumulative and
in addition to those rights and remedies available under Sections 19.2.1 and 19.2.2, or any Law or other provision hereof), without prior demand or notice except as required by Law, to seek any declaratory, injunctive or other
equitable relief, and specifically enforce this Lease, or restrain or enjoin a violation or breach of any provision hereof. 

19.3 Efforts to Relet. Unless Landlord provides Tenant with express notice to the contrary, no re-entry, repossession,
repair, maintenance, change, alteration, addition, reletting, appointment of a receiver or other action or omission by Landlord shall (a) be construed as an election by Landlord to terminate this Lease or Tenant’s right to possession, or
to accept a surrender of the Premises, or (b) operate to release Tenant from any of its obligations hereunder. Tenant waives, for Tenant and for all those claiming by, through or under Tenant, California Civil Code § 3275 and
California Code of Civil Procedure §§ 1174(c) and 1179 and any existing or future rights to redeem or reinstate, by order or judgment of any court or by any legal process or writ, this Lease or Tenant’s right of occupancy of the
Premises after any termination hereof. 
 19.4 Landlord Default. Landlord shall not be in default hereunder unless
it breaches a provision hereof and such breach continues for 30 days after notice from Tenant; provided that if such breach cannot reasonably be cured within such 30-day period, Landlord shall not be in default as a result of such breach if
Landlord diligently commences such cure within such period, thereafter diligently pursues such cure, and completes such cure within 60 days after Tenant’s notice. Before exercising any remedies for a default by Landlord, Tenant shall give
notice and a reasonable time to cure to any Security Holder of which Tenant has been notified. 
 20     LANDLORD
EXCULPATION. Notwithstanding any contrary provision hereof, (a) the liability of the Landlord Parties to Tenant shall be limited to an amount equal to the lesser of (i) Landlord’s interest in the Building, or (ii) the equity
interest Landlord would have in the Building if the Building were encumbered by third-party debt in an amount equal to 75% of the value of the Building (as such value is determined by Landlord); (b) Tenant shall look solely to
Landlord’s interest in the Building for the recovery of any judgment or award against any Landlord Party; (c) no Landlord Party shall have any personal liability for any judgment or deficiency, and Tenant waives and releases such personal
liability on behalf of itself and all parties claiming by, through or under Tenant; and (d) no Landlord Party shall be liable for any injury or damage to, or interference with, Tenant’s business, including loss of profits, loss of rents or
other revenues, loss of business opportunity, loss of goodwill or loss of use, or for any form of special or consequential damage. 
 21
    SECURITY DEPOSIT. Concurrently with its execution and delivery hereof, Tenant shall deposit with Landlord the Security Deposit, if any, as security for Tenant’s performance of its obligations hereunder. If Tenant
breaches any provision hereof, Landlord may, at its option, without notice to Tenant, apply all or part of the Security Deposit to pay any past-due Rent, cure any breach by Tenant, or compensate Landlord for any other loss or damage caused by such
breach. If Landlord so applies any portion of the Security Deposit, Tenant, within five (5) business days after demand therefor, shall restore the Security Deposit to its original amount. The Security Deposit is not an advance payment of Rent
or measure of damages. Any unapplied portion of the Security Deposit shall be returned to Tenant within 60 days after the latest to occur of (a) the expiration of the Term, (b) Tenant’s surrender of the Premises as required
hereunder, or (c) determination of the final Rent due from Tenant. Landlord shall not be required to keep the Security Deposit separate from its other accounts. 

  
 19 








 22     RELOCATION. INTENTIONALLY OMITTED. 

23     COMMUNICATIONS AND COMPUTER LINES. All Lines installed pursuant to this Lease shall be (a) installed in
accordance with Section 7; and (b) clearly marked with adhesive plastic labels (or plastic tags attached to such Lines with wire) to show Tenant’s name, suite number, and the purpose of such Lines (i) every six (6)
feet outside the Premises (including the electrical room risers and any Common Areas), and (ii) at their termination points. Landlord may designate specific contractors for work relating to vertical Lines. Sufficient spare cables and space for
additional cables shall be maintained for other occupants, as reasonably determined by Landlord. Unless otherwise notified by Landlord, Tenant, at its expense and before the expiration or earlier termination hereof, shall remove all Lines and repair
any resulting damage. As used herein, “Lines” means all communications or computer wires and cables serving the Premises, whenever and by whomever installed or paid for, including any such wires or cables installed pursuant to any
prior lease. 
 24     PARKING. Tenant may park in the Building’s parking facilities (the
“Parking Facility”), in common with other tenants of the Building, upon the following terms and conditions. Tenant shall not use more than the number of unreserved and/or reserved parking passes set forth in Section 1.9.
Tenant shall pay Landlord, in accordance with Section 3, any fees for the parking passes described in Section 1.9. Tenant shall pay Landlord any fees, taxes or other charges imposed by any governmental or quasi-governmental
agency in connection with the Parking Facility, to the extent such amounts are reasonably and properly allocated to Tenant by Landlord. Landlord shall not be liable to Tenant, nor shall this Lease be affected, if any parking is impaired by (or any
parking charges are imposed as a result of) any Law. Tenant shall comply with all non-discriminatory rules and regulations established by Landlord from time to time for the orderly operation and use of the Parking Facility, including any sticker or
other identification system and the prohibition of vehicle repair and maintenance activities in the Parking Facility. Landlord may, in its discretion, allocate and assign parking passes among Tenant and the other tenants in the Building.
Tenant’s use of the Parking Facility shall be at Tenant’s sole risk, and Landlord shall have no liability for any personal injury or damage to or theft of any vehicles or other property occurring in the Parking Facility or otherwise in
connection with any use of the Parking Facility by Tenant, its employees or invitees, except to the extent caused by Landlord’s negligence or willful misconduct. Landlord may alter the size, configuration, design, layout or any other aspect of
the Parking Facility, and, in connection therewith, temporarily deny or restrict access to the Parking Facility, in each case without abatement of Rent or liability to Tenant, except as otherwise provided herein. Landlord may delegate its
responsibilities hereunder to a parking operator, in which case (i) such parking operator shall have all the rights of control reserved herein by Landlord, (ii) Tenant shall enter into a parking agreement with such parking operator
consistent with the terms hereof, (iii) Tenant shall pay such parking operator, rather than Landlord, any charge established hereunder for the parking passes, and (iv) Landlord shall have no liability for claims arising through acts or
omissions of such parking operator except to the extent caused by Landlord’s negligence or willful misconduct. Tenant’s parking rights under this Section 24 are solely for the benefit of Tenant’s employees and invitees and
such rights may not be transferred without Landlord’s prior consent, except pursuant to a Transfer permitted under Section 14. 

25     MISCELLANEOUS. 
 25.1 Notices. No notice, demand, statement, designation, request, consent, approval, election or other communication given hereunder (“Notice”) shall be binding upon either
party unless (a) it is in writing; (b) it is (i) sent by certified or registered mail, postage prepaid, return receipt requested, (ii) delivered by a nationally recognized courier service, or (iii) delivered personally; and
(c) it is sent or delivered to the address set forth in Section 1.10 or 1.11, as applicable, or to such other place (other than a P.O. box) as the recipient may from time to time designate in a Notice to the other party.
Any Notice shall be deemed received on the earlier of the date of actual delivery or the date on which delivery is refused, or, if Tenant is the recipient and has vacated its notice address without providing a new notice address, three (3) days
after the date the Notice is deposited in the U.S. mail or with a courier service as described above. 
 25.2 Force
Majeure. If either party is prevented from performing any obligation hereunder by any strike, act of God, war, terrorist act, shortage of labor or materials, governmental action, civil commotion or other cause beyond such party’s
reasonable control (“Force Majeure”), such obligation shall be excused during (and any time period for the performance of such obligation shall be extended by) the period of such prevention; provided, however, that this
Section 25.2 shall not (a) permit Tenant to hold over in the Premises after the expiration or earlier termination hereof, or (b) excuse any of Tenant’s obligations under Sections 3, 4, 21 or
25.3. 
 25.3 Representations and Covenants. Tenant represents, warrants and covenants that (a) Tenant
is, and at all times during the Term will remain, duly organized, validly existing and in good standing under the Laws of the state of its formation and qualified to do business in the state of California; (b) neither Tenant’s execution of
nor its performance under this Lease will cause Tenant to be in violation of any agreement or Law; (c) Tenant (and any guarantor hereof) has not, and at no time during the Term will have, (i) made a general assignment for the benefit of
creditors, (ii) filed a voluntary petition in bankruptcy or suffered the filing of an involuntary petition by creditors, (iii) suffered the appointment of a 

  
 20 








 
receiver to take possession of all or substantially all of its assets, (iv) suffered the attachment or other judicial seizure of all or substantially all of its assets, (v) admitted in
writing its inability to pay its debts as they come due, or (vi) made an offer of settlement, extension or composition to its creditors generally; and (d) each party that (other than through the passive ownership of interests traded on a
recognized securities exchange) constitutes, owns, controls, or is owned or controlled by Tenant, any guarantor hereof or any subtenant of Tenant is not, and at no time during the Term will be, (i) in violation of any Laws relating to terrorism
or money laundering, or (ii) among the parties identified on any list compiled pursuant to Executive Order 13224 for the purpose of identifying suspected terrorists or on the most current list published by the U.S. Treasury Department Office of
Foreign Assets Control at its official website, http://www.treas.gov/ofac/tllsdn.pdf or any replacement website or other replacement official publication of such list. 
 25.4 Signs. Tenant shall be entitled to 11 lines on the tenant directory located in the lobby on the first floor of the Building. If any part of the Premises is located on a multi-tenant
floor, Landlord, at Tenant’s cost (subject to the Allowance (as defined in Exhibit B)), shall provide identifying suite signage for Tenant comparable to that provided by Landlord on similar floors in the Building. Tenant may not
install (a) any signs outside the Premises, or (b) without Landlord’s prior consent in its sole and absolute discretion, any signs, window coverings, blinds or similar items that are visible from outside the Premises. Landlord and
Tenant acknowledge and agree that Tenant shall have the right to have their entrance doors of the Premises facing the elevator lobby open during Building HVAC Hours (provided such entryway doors are equipped with emergency release hold open devices
that is tied in with the fire life safety system. 
 25.5 Supplemental HVAC. If any supplemental HVAC unit (a
“Unit”) serves the Premises, then (a) Tenant shall pay the costs of all electricity consumed in the Unit’s operation, together with the cost of installing a meter to measure such consumption; (b) Tenant, at its
expense, shall (i) operate and maintain the Unit in compliance with all applicable Laws and such reasonable rules and procedures as Landlord may impose; (ii) keep the Unit in as good working order and condition as exists upon its
installation (or, if later, on the date Tenant takes possession of the Premises), subject to normal wear and tear and damage resulting from Casualty; (iii) maintain in effect, with a contractor reasonably approved by Landlord, a contract for
the maintenance and repair of the Unit, which contract shall require the contractor, at least once every three (3) months, to inspect the Unit and provide to Tenant a report of any defective conditions, together with any recommendations for
maintenance, repair or parts-replacement; (iv) follow all reasonable recommendation of such contractor; and (v) promptly provide to Landlord a copy of such contract and each report issued thereunder; (c) the Unit shall become
Landlord’s property upon installation and without compensation to Tenant; provided, however, that upon Landlord’s request at the expiration or earlier termination hereof, Tenant, at its expense, shall remove the Unit and repair any
resulting damage. Notwithstanding the foregoing, Tenant shall have no obligation to remove the Unit that is located in the Premises as of the date of this Lease; (d) the Unit shall be deemed (i) a Leasehold Improvement (except for purposes
of Section 8), and (ii) for purposes of Section 11, part of the Premises; (e) if the Unit exists on the date of mutual execution and delivery hereof, Tenant accepts the Unit in its “as is” condition,
without representation or warranty as to quality, condition, fitness for use or any other matter; and (f) if the Unit connects to the Building’s condenser water loop (if any), then Tenant shall pay to Landlord, as Additional Rent,
Landlord’s standard (i.e., the same rate charged to other tenants for such connection) monthly per-ton usage fee (currently $150.00 per ton). 
 25.6 Attorneys’ Fees. In any action or proceeding between the parties, including any appellate or alternative dispute resolution proceeding, the prevailing party may recover from the
other party all of its costs and expenses in connection therewith, including reasonable attorneys’ fees and costs. Tenant shall pay all reasonable attorneys’ fees and other fees and costs that Landlord incurs in enforcing this Lease or
otherwise protecting its rights hereunder (a) where Tenant has failed to pay Rent when due, or (b) in any bankruptcy case, assignment for the benefit of creditors, or other insolvency, or liquidation proceeding involving Tenant or this
Lease. 
 25.7 Brokers. Tenant represents to Landlord that it has dealt only with Tenant’s Broker as its
broker in connection with this Lease. Tenant shall indemnify, defend, and hold Landlord harmless from all claims of any brokers, other than Tenant’s Broker, claiming to have represented Tenant in connection with this Lease. Landlord shall
indemnify, defend and hold Tenant harmless from all claims of any brokers, including Landlord’s Broker, claiming to have represented Landlord in connection with this Lease. Tenant acknowledges that any Affiliate of Landlord that is involved in
the negotiation of this Lease is representing only Landlord, and that any assistance rendered by any agent or employee of such Affiliate in connection with this Lease or any subsequent amendment or other document related hereto has been or will be
rendered as an accommodation to Tenant solely in furtherance of consummating the transaction on behalf of Landlord, and not as agent for Tenant. 
 25.8 Governing Law; WAIVER OF TRIAL BY JURY. This Lease shall be construed and enforced in accordance with the Laws of the State of California. THE PARTIES WAIVE, TO THE FULLEST EXTENT
PERMITTED BY LAW, THE RIGHT TO TRIAL BY JURY IN ANY LITIGATION ARISING OUT OF OR RELATING TO THIS LEASE, THE RELATIONSHIP OF 

  
 21 








 
LANDLORD AND TENANT, TENANT’S USE OR OCCUPANCY OF THE PREMISES, AND/OR ANY CLAIM FOR INJURY OR DAMAGE OR ANY EMERGENCY OR STATUTORY REMEDY. 

25.9 Waiver of Statutory Provisions. Each party waives California Civil Code §§ 1932(2)
and 1933(4). Tenant waives (a) any rights under (i) California Civil Code §§ 1932(1), 1941, 1942, 1950.7 or any similar Law, or (ii) California Code of Civil Procedure § 1265.130; and (b) any
right to terminate this Lease under California Civil Code § 1995.310. 
 25.10 Interpretation. As used
herein, the capitalized term “Section” refers to a section hereof unless otherwise specifically provided herein. As used in this Lease, the terms “herein,” “hereof,” “hereto” and “hereunder” refer to
this Lease and the term “include” and its derivatives are not limiting. Any reference herein to “any part” or “any portion” of the Premises, the Property or any other property shall be construed to refer to all or any
part of such property. Wherever this Lease requires Tenant to comply with any Law, rule, regulation, procedure or other requirement or prohibits Tenant from engaging in any particular conduct, this Lease shall be deemed also to require Tenant to
cause each of its employees, licensees, invitees and subtenants, and any other party claiming by, through or under Tenant, to comply with such requirement or refrain from engaging in such conduct, as the case may be. Wherever this Lease requires
Landlord to provide a customary service or to act in a reasonable manner (whether in incurring an expense, establishing a rule or regulation, providing an approval or consent, or performing any other act), this Lease shall be deemed also to provide
that whether such service is customary or such conduct is reasonable shall be determined by reference to the practices of owners of buildings that (i) are comparable to the Building in size, age, class, quality and location, and (ii) if
applicable, have been, or are being prepared to be, certified under the U.S. Green Building Council’s Leadership in Energy and Environmental Design (LEED) rating system or a similar rating system. Tenant waives the benefit of any rule that
a written agreement shall be construed against the drafting party. 
 25.11 Entire Agreement. This Lease sets
forth the entire agreement between the parties relating to the subject matter hereof and supersedes any previous agreements (none of which shall be used to interpret this Lease). Tenant acknowledges that in entering into this Lease it has not relied
upon any representation, warranty or statement, whether oral or written, not expressly set forth herein. This Lease can be modified only by a written agreement signed by both parties. 

25.12 Other. Landlord, at its option, may cure any Default, without waiving any right or remedy or releasing Tenant from
any obligation, in which event Tenant shall pay Landlord, upon demand, the reasonable out-of-pocket cost incurred by Landlord of such cure. If any provision hereof is void or unenforceable, no other provision shall be affected. Submission of this
instrument for examination or signature by Tenant does not constitute an option or offer to lease, and this instrument is not binding until it has been executed and delivered by both parties. If Tenant is comprised of two or more parties, their
obligations shall be joint and several. Time is of the essence with respect to the performance of every provision hereof in which time of performance is a factor. So long as Tenant performs its obligations hereunder, Tenant shall have peaceful and
quiet possession of the Premises against any party claiming by, through or under Landlord, subject to the terms hereof. Landlord may transfer its interest herein, in which event Landlord shall be released from, Tenant shall look solely to the
transferee for the performance of, and the transferee shall be deemed to have assumed (and shall assume in writing), all of Landlord’s obligations arising hereunder after the date of such transfer (including the return of any Security Deposit,
LC Proceeds Account and any Letter of Credit or Renewal or Replacement LC) and Tenant shall attorn to the transferee. Landlord reserves all rights not expressly granted to Tenant hereunder, including the right to make alterations to the Project;
provided that Tenant’s rights under this Lease are not reduced and Tenant’s obligations hereunder are not increased and Tenant’s use of, parking for or access to the Premises is not affected thereby. No rights to any view or to light
or air over any property are granted to Tenant hereunder. The expiration or termination hereof shall not relieve either party of any obligation that accrued before, or continues to accrue after, such expiration or termination. 

[SIGNATURES ARE ON THE FOLLOWING PAGE] 

  
 22 








 IN WITNESS WHEREOF, Landlord and Tenant have caused this Lease to be executed the day and
date first above written. 
  

					
	LANDLORD:
	
	CA-10880 WILSHIRE LIMITED PARTNERSHIP, a Delaware limited partnership
		
	By:	 	EOP Owner GP L.L.C., a Delaware limited liability company, its general partner
			
		 	By:	 	 /s/ Frank Campbell

		 		 	Name: Frank Campbell
		 		 	Title: Market Managing Director
	
	TENANT:
	
	PUMA BIOTECHNOLOGY, INC., a Delaware corporation
		
	By:	 	 /s/ Alan H. Auerbach

	Name:	 	Alan H. Auerbach
	Title:	 	Chief Executive Officer and President
		
	By:	 	 /s/ Charles Eyler

	Name:	 	Charles Eyler
	Title:	 	Senior Vice President – Finance & Treasurer



  
 23 








 EXHIBIT A 

10880 WILSHIRE BOULEVARD 
 OUTLINE OF PREMISES 
 



 
  

  
 Exhibit A

 1 







 EXHIBIT B 

10880 WILSHIRE BOULEVARD 
 WORK LETTER 
 As used in this Exhibit B (this
“Work Letter”), the following terms shall have the following meanings: “Agreement” means the Lease of which this Work Letter is a part. “Tenant Improvements” means all improvements to be constructed
in the Premises pursuant to this Work Letter. “Tenant Improvement Work” means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  

	1	ALLOWANCE. 

 1.1
Allowance. Tenant shall be entitled to a one-time tenant improvement allowance (the “Allowance”) in the amount of $675,954.00 (i.e. $51.00 per rentable square foot of the Premises) to be applied toward the
Allowance Items (defined in Section 1.2 below). Tenant shall be responsible for all costs associated with the Tenant Improvement Work, including the costs of the Allowance Items, to the extent such costs exceed the lesser of (a) the
Allowance, or (b) the aggregate amount that Landlord is required to disburse for such purpose pursuant to this Work Letter. Notwithstanding any contrary provision of this Agreement, if Tenant fails to use the entire Allowance in
connection with the performance of the Tenant Improvement Work, the unused amount shall revert to Landlord and Tenant shall have no further rights with respect thereto. 
 1.2 Disbursement of the Allowance. Except as otherwise provided in this Work Letter, the Allowance shall be disbursed by Landlord only for the following items (the “Allowance
Items”): (a) the fees of the Architect (defined in Section 2.1 below) and the Engineers, and any fees reasonably incurred by Landlord for review of the Plans (defined in Section 2.1 below) by Landlord’s
third party consultants; (b) plan-check, permit and license fees relating to performance of the Tenant Improvement Work; (c) the cost of performing the Tenant Improvement Work, including after-hours charges, testing and inspection costs,
and trash removal costs, and contractors’ fees and general conditions; (d) the cost of any change to the base, shell or core of the Premises or Building required by the Plans (including if such change is due to the fact that such work is
prepared on an unoccupied basis), including all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) the cost of any change to the Plans or Tenant Improvement Work required by Law; (f) the
Landlord Supervision Fee (defined in Section 3.2.2 below); (g) sales and use taxes; (h) project management fees and the fees of any other consultant retained by Tenant in connection with the Tenant Improvement Work,
(i) the cost of purchasing and installing furniture, fixtures and equipment in the Premises; (j) the cost of purchasing and installing telecommunications and data cabling in the Premises, and (k) all other costs expended by Landlord
in connection with the performance of the Tenant Improvement Work. Notwithstanding the foregoing, in no event may Tenant apply more than a total of $238,572.00 (i.e. $18.00 per rentable square foot of the Premises) toward the costs described
in (a), (h), (i) and (j) above. 
 1.3 In addition to the above described Allowance, Landlord agrees to provide Tenant
with a space planning allowance (the “Space Planning Allowance”) in an amount not to exceed $1,590.48 to be applied toward the cost of the preparation of a preliminary space plan for the Premises to be prepared by the Architect
(defined below). If the Space Planning Allowance exceeds the cost of the preparation of the preliminary plan, any remaining Space Planning Allowance shall accrue to the sole benefit of Landlord, it being agreed that Tenant shall not be entitled to
any credit, offset, abatement or payment with respect thereto. The Space Planning Allowance shall be paid to Tenant on or before the later of (i) thirty (30) days after the date Landlord approves the final Plans for the Tenant Improvement
Work, or (ii) thirty (30) days after Landlord’s receipt of a paid invoice with respect to the cost of preparing the preliminary space plan. 
  

	2	PLANS AND PRICING. 

 2.1
Selection of Architect. Tenant shall retain SAA as the architect/space planner (the “Architect”) and engineering consultants approved by Landlord (the “Engineers”) to prepare all architectural plans
for the Premises and all engineering working drawings relating to the structural, mechanical, electrical, plumbing, HVAC, life-safety, and sprinkler work in the Premises. The plans and drawings to be prepared by the Architect and the Engineers shall
be referred to in this Work Letter as the “Plans.” All Plans shall (a) comply with the drawing format and specifications required by Landlord, (b) be consistent with Landlord’s requirements for avoiding aesthetic,
engineering or other conflicts with the design and function of the balance of the Building, and (c) otherwise be subject to Landlord’s reasonable approval. Notwithstanding any review of the Plans by Landlord or any of its space planners,
architects, engineers or other consultants, and notwithstanding any advice or assistance that may be rendered to Tenant by Landlord or any such consultant, Landlord shall not be liable for any error or


  
 Exhibit B

 1 







 
omission in the Plans or have any other liability relating thereto. Without limiting the foregoing, Tenant shall be responsible for ensuring (x) that all elements of the design of the Plans
comply with Law and are otherwise suitable for Tenant’s use of the Premises, and (y) that no Tenant Improvement impairs any system or structural component of the Building, and neither Landlord’s nor its consultants’ approval of
the Plans shall relieve Tenant from such responsibility. 
 2.2 [Intentionally Omitted.] 

2.3 Space Plan. Landlord and Tenant have approved the space plan attached hereto as Exhibit B-1 (the “Space
Plan”). 
 2.4 [Intentionally Omitted.] 

2.5 Construction Drawings. Tenant shall cause the Architect and the Engineers to complete the architectural, engineering
and final architectural working drawings for the Tenant Improvement Work in a form that is sufficient to enable subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Construction Drawings”), and,
no later than 10 days after the execution of the Lease by Landlord and Tenant, shall deliver four (4) copies of the Construction Drawings, signed by Tenant, to Landlord for its approval. Notwithstanding the foregoing, at Tenant’s option,
the Construction Drawings may be prepared in two phases (first the architectural drawings, then engineering drawings consistent with the previously provided architectural drawings), provided that each phase shall be subject to Landlord’s
approval. Landlord shall provide Tenant with notice approving or reasonably disapproving the Construction Drawings (or the applicable component thereof) within 10 business days after the later of Landlord’s receipt thereof or the mutual
execution and delivery of this Agreement. If Landlord disapproves the Construction Drawings (or any component thereof), Landlord’s notice of disapproval shall describe with reasonable specificity the basis for such disapproval and the changes
that would be necessary to resolve Landlord’s objections. If Landlord disapproves the Construction Drawings (or any component thereof), Tenant shall cause the Construction Drawings to be modified and resubmitted to Landlord for its approval.
Such procedure shall be repeated as necessary until Landlord has approved the Construction Drawings (or the applicable component thereof). No revision may be made to the approved Construction Drawings (the “Approved Construction
Drawings”) without Landlord’s prior consent, which shall not be unreasonably withheld. 
 2.6 Construction
Pricing. Within a reasonable time after the Approved Construction Drawings are approved by Landlord and Tenant, Landlord shall provide Tenant with Landlord’s reasonable estimate (the “Construction Pricing Proposal”) of
the cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to the Approved Construction Drawings. Tenant shall provide Landlord with notice approving or disapproving the
Construction Pricing Proposal. If Tenant disapproves the Construction Pricing Proposal, Tenant’s notice of disapproval shall be accompanied by proposed revisions to the Approved Construction Drawings that Tenant requests in order to resolve its
objections to the Construction Pricing Proposal, and Landlord shall respond as required under Section 2.7 below. Such procedure shall be repeated as necessary until the Construction Pricing Proposal is approved by Tenant. Upon
Tenant’s approval of the Construction Pricing Proposal, Landlord may purchase the items set forth in the Construction Pricing Proposal and, to the extent any required Permits have been delivered to Landlord, commence construction relating to
such items. 
 2.7 Revisions to Approved Construction Drawings. If Tenant requests Landlord’s approval of any
revision to the Approved Construction Drawings, Landlord shall provide Tenant with notice approving or reasonably disapproving such revision, and, if Landlord approves such revision, Landlord shall provide Tenant with notice of any resulting change
in the most recent Construction Pricing Proposal, if any, within 5 business days after Landlord’s receipt of such request (together with the proposed revision) if such revision is not material, and within such longer period of time as may
be reasonably necessary (but not more than 10 business days after receipt) if such revision is material, whereupon Tenant, within one (1) business day, shall notify Landlord whether it desires to proceed with such revision. If Landlord has
commenced performance of the Tenant Improvement Work, then, in the absence of such authorization, Landlord shall have the option to continue such performance disregarding such revision. 

2.8 Permits. Tenant shall submit the Approved Construction Drawings to the appropriate municipal authorities and otherwise
apply for and obtain from such authorities, and deliver to Landlord, all permits necessary to enable the Contractor (defined in Section 3.1 below) to complete the Tenant Improvement Work (the “Permits”). Tenant shall
coordinate with Landlord in order to allow Landlord, at its option, to take part in all phases of the permitting process and shall supply Landlord, as soon as possible, with all plan check numbers and dates of submittal. Notwithstanding any contrary
provision hereof, Tenant, and not Landlord or its consultants, shall be responsible for obtaining any Permit or certificate of occupancy; provided, however, that Landlord shall cooperate with Tenant in executing


  
 Exhibit B

 2 







 
permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any Permit or certificate of occupancy. 

2.9 Time Deadlines. Tenant shall use commercially reasonable efforts to cooperate with its architect, engineers and other
consultants, and with Landlord and its contractors and consultants, to complete all phases of the Plans, approve the Construction Pricing Proposal and obtain the Permits as soon as possible after the execution of this Agreement, and Tenant shall
meet with Landlord, in accordance with a schedule mutually agreed upon by Landlord and Tenant, to discuss Tenant’s progress. Without limiting the foregoing, Tenant shall approve the Construction Pricing Proposal pursuant to
Section 2.6 above and deliver the Permits to Landlord pursuant to Section 2.8 above on or before Tenant’s Approval and Permitting Deadline (defined below). As used in this Work Letter, “Tenant’s Approval and
Permitting Deadline” means 14 days after the parties approval of the Approved Construction Drawings; provided, however, that Tenant’s Approval and Permitting Deadline shall be extended by one day for each day, if any, by which the date
on which Tenant approves the Construction Pricing Proposal pursuant to Section 2.6 above and delivers the Permits to Landlord pursuant to Section 2.8 above is delayed by any failure of Landlord to perform its obligations
under this Section 2. 
  

	3	CONSTRUCTION. 

 3.1
Contractor. Landlord shall retain Holwick (the “Contractor”) as the general contractor to perform the Tenant Improvement Work. Landlord shall cause contractor to competitively bid all major subcontracts to not less than three
(3) qualified subcontractors with the exception that Landlord shall not be required to competitively bid work to be performed by the Building’s fire life safety vendor.. 

3.2 Construction. 
 3.2.1 Over-Allowance Amount. If the Construction Pricing Proposal exceeds the Allowance, then, concurrently with its delivery to Landlord of approval of the Construction Pricing Proposal, Tenant
shall deliver to Landlord cash in the amount of such excess (the “Over-Allowance Amount”). Any Over-Allowance Amount shall be disbursed by Landlord before the Allowance and pursuant to the same procedure as the Allowance. After the
Construction Pricing Proposal is approved by Tenant, if any revision is made to the Approved Construction Drawings or the Tenant Improvement Work that increases the Construction Pricing Proposal, or if the Construction Pricing Proposal is otherwise
increased to reflect the actual cost of all Allowance Items to be incurred by Tenant in connection with the performance of the Tenant Improvement Work pursuant to the Approved Construction Drawings, then Tenant shall deliver any resulting
Over-Allowance Amount (or any resulting increase in the Over-Allowance Amount) to Landlord immediately upon Landlord’s request. 
 3.2.2 Landlord’s Retention of Contractor. Landlord shall independently retain the Contractor to perform the Tenant Improvement Work in accordance with the Approved Construction Drawings.
Tenant shall pay a construction supervision and management fee (the “Landlord Supervision Fee”) to Landlord in an amount equal to 5% of the aggregate amount of all Allowance Items other than the Landlord Supervision Fee. 

3.2.3 Contractor’s Warranties. Tenant waives all claims against Landlord relating to any defects in the Tenant Improvements;
provided, however, that if, after substantial completion of the Tenant Improvements, Tenant provides notice to Landlord of any non-latent defect in the Tenant Improvements, or if, after substantial completion of the Tenant Improvements, Tenant
provides notice to Landlord of any latent defect in the Tenant Improvements, then Landlord shall, at its option, either (a) assign to Tenant any right Landlord may have under the Construction Contract (defined below) to require the Contractor
to correct, or pay for the correction of, such defect, or (b) at Tenant’s expense, use reasonable efforts to enforce such right directly against the Contractor for Tenant’s benefit. As used in this Work Letter, “Construction
Contract” means the construction contract between Landlord and the Contractor pursuant to which the Tenant Improvements will be constructed. 
 3.2.4 Tenant’s Covenants. At the conclusion of construction, Tenant shall cause the Architect to (i) update the Approved Construction Drawings as necessary to reflect all changes made to
the Approved Construction Drawings during the course of construction, (ii) certify to the best of its knowledge that the updated drawings are true and correct, which certification shall survive the expiration or termination of the Lease, and
(iii) deliver to Landlord two (2) CD ROMS of such updated drawings in accordance with Landlord’s CAD Format Requirements (defined below) within 30 days following issuance of a certificate of occupancy for the Premises. For
purposes of this Work Letter, “Landlord’s CAD Format Requirements” shall mean (w) the version is no later than current Autodesk version of AutoCAD plus the most recent release version, (x) files must be unlocked
and fully accessible (no “cad-lock”, read-only, password protected or “signature” files), (y) files must be in “.dwg” format, and (z) if the data was electronically in a non-Autodesk product, then files must
be converted into “dwg” files when given to Landlord. 

  
 Exhibit B

 3 







 3.2.5 Landlord shall provide to Contractor and all subcontractors, without additional
charge, parking, utilities, HVAC during normal Business Hours, freight elevator service, use of the loading docks, and restrooms, during the construction of the Tenant Improvement Work and during Tenant’s move into the Premises. 

 

	4	COMPLETION. 

 4.1
Ready for Occupancy. For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to
Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by
Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises. 

4.2 Tenant Delay. If the substantial completion of the Tenant Improvement Work is delayed (a “Tenant
Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above and deliver the Permits to Landlord pursuant to Section 2.8 above on or before
Tenant’s Approval and Permitting Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any change (or Tenant’s
request for Landlord’s approval of any change) in the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s
requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of substantial completion of the Tenant Improvement Work as set forth in this Agreement; or
(f) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually substantially completed,
the Tenant Improvement Work shall be deemed to be substantially completed on the date on which the Tenant Improvement Work would have been substantially completed if no such Tenant Delay had occurred. 

5     MISCELLANEOUS. Notwithstanding any contrary provision of this Agreement, if Tenant defaults under this Agreement before
the Tenant Improvement Work is completed, Landlord’s obligations under this Work Letter shall be excused until such default is cured and Tenant shall be responsible for any resulting delay in the completion of the Tenant Improvement Work. This
Work Letter shall not apply to any space other than the Premises. 

  
 Exhibit B

 4 







 EXHIBIT C 

10880 WILSHIRE BOULEVARD 
 CONFIRMATION LETTER 

                        ,
2011 
 PUMA BIOTECHNOLOGY, INC. 

10880 Wilshire Boulevard 
 Suite 2150 

Los Angeles, California 
  

	Re:	Office Lease (the “Lease”) dated
                        , 2011, between CA-10880 WILSHIRE LIMITED PARTNERSHIP, a Delaware limited partnership
(“Landlord”), and PUMA BIOTECHNOLOGY, INC., a Delaware corporation (“Tenant”), concerning Suite 2150 (the “Premises”) on the 21ST floor of the building located at 10880 Wilshire
Boulevard, Los Angeles, California. 

 Lease ID:
                                         
        
 Business Unit Number:
                           
 Dear
                                : 

In accordance with the Lease, Tenant accepts possession of the Premises and confirms the following: 

 

	 	1.	The Commencement Date is
                         and the Expiration Date is
                        . 

 Please acknowledge the foregoing by signing all three (3) counterparts of this letter in the space provided below and returning two (2) fully executed counterparts to my attention. Please note
that, pursuant to Section 2.1.1 of the Lease, if Tenant fails to execute and return (or, by notice to Landlord, reasonably object to) this letter within 10 days after receiving it, Tenant shall be deemed to have executed and returned it without
exception. 
  

									
	  
 Agreed and Accepted as of
                        , 2011.
  

“Tenant”:
  
 PUMA BIOTECHNOLOGY, INC., a Delaware corporation
	  	 “Landlord”:
  

EQUITY OFFICE MANAGEMENT, L.L.C.,
 as
agent for CA-10880 Wilshire Limited Partnership

		 		  	By:	 	  

		 		  		 	Name:	 	  

	By: 	 	  
	  		 	Title:	 	Authorized Signatory
	Name:	 	  
	  		 		 	
	Title:	 	  
	  		 		 	


  
 Exhibit C

 1 







 EXHIBIT D 

10880 WILSHIRE BOULEVARD 
 RULES AND REGULATIONS 
 Tenant shall comply with the following rules
and regulations (as modified or supplemented from time to time, the “Rules and Regulations”). Landlord shall not be responsible to Tenant for the nonperformance of any of the Rules and Regulations by any other tenants or occupants
of the Project, provided that Landlord shall enforce the rules and regulations for the Building in good faith and in a non-discriminatory manner with respect to all tenants of the Building. In the event of any conflict between the Rules and
Regulations and the other provisions of this Lease, the latter shall control. 
 1. Tenant shall not alter any lock or install
any new or additional locks or bolts on any doors or windows of the Premises without obtaining Landlord’s prior consent. Tenant shall bear the cost of any lock changes or repairs required by Tenant. Two (2) keys will be furnished by
Landlord for the Premises, and any additional keys required by Tenant must be obtained from Landlord at a reasonable cost to be established by Landlord. Upon the termination of this Lease, Tenant shall restore to Landlord all keys of stores, offices
and toilet rooms furnished to or otherwise procured by Tenant, and if any such keys are lost, Tenant shall pay Landlord the cost of replacing them or of changing the applicable locks if Landlord deems such changes necessary. 

2. All doors opening to public corridors shall be kept closed at all times except for normal ingress and egress to the Premises.

 3. Landlord may close and keep locked all entrance and exit doors of the Building during such hours as are customary for
comparable buildings in the vicinity of the Building. Tenant shall cause its employees, agents, contractors, invitees and licensees who use Building doors during such hours to securely close and lock them after such use. Any person entering or
leaving the Building during such hours, or when the Building doors are otherwise locked, may be required to sign the Building register, and access to the Building may be refused unless such person has proper identification or has a previously
arranged access pass. Landlord will furnish passes to persons for whom Tenant requests them. Tenant shall be responsible for all persons for whom Tenant requests passes and shall be liable to Landlord for all acts of such persons. Landlord and its
agents shall not be liable for damages for any error with regard to the admission or exclusion of any person to or from the Building. In case of invasion, mob, riot, public excitement or other commotion, Landlord may prevent access to the Building
or the Project during the continuance thereof by any means it deems appropriate for the safety and protection of life and property. 
 4. No furniture, freight or equipment shall be brought into the Building without prior notice to Landlord. All moving activity into or out of the Building shall be scheduled with Landlord and done only at
such time and in such manner as Landlord designates. Landlord may prescribe the weight, size and position of all safes and other heavy property brought into the Building and also the times and manner of moving the same in and out of the Building.
Safes and other heavy objects shall, if considered necessary by Landlord, stand on supports of such thickness as is necessary to properly distribute the weight. Landlord will not be responsible for loss of or damage to any such safe or property. Any
damage to the Building, its contents, occupants or invitees resulting from Tenant’s moving or maintaining any such safe or other heavy property shall be the sole responsibility and expense of Tenant (notwithstanding Sections 7 and
10.4 of this Lease). 
 5. No furniture, packages, supplies, equipment or merchandise will be received in the Building or
carried up or down in the elevators, except in such specific elevator and by such personnel as shall be designated by Landlord. 

6. Employees of Landlord shall not perform any work or do anything outside their regular duties unless under special instructions from
Landlord. 
 7. No sign, advertisement, notice or handbill shall be exhibited, distributed, painted or affixed by Tenant on any
part of the Premises or the Building without Landlord’s prior consent. Tenant shall not disturb, solicit, peddle or canvass any occupant of the Project. 
 8. The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they were constructed, and no foreign substance shall be thrown therein.
Notwithstanding Sections 7 and 10.4 of this Lease, Tenant shall bear the expense of any breakage, stoppage or damage resulting from any violation of this rule by Tenant or any of its employees, agents, contractors, invitees or
licensees. 

  
 Exhibit D

 1 







 9. Tenant shall not overload the floor of the Premises, or mark, drive nails or screws or
drill into the partitions, woodwork or drywall of the Premises, or otherwise deface the Premises, without Landlord’s prior consent. Tenant shall not purchase bottled water, ice, towel, linen, maintenance or other like services from any person
not approved by Landlord. 
 10. Except for vending machines intended for the sole use of Tenant’s employees and invitees,
no vending machine or machines other than fractional horsepower office machines shall be installed, maintained or operated in the Premises without Landlord’s prior consent. 

11. No inflammable, explosive or dangerous fluids or substances shall be used or kept by Tenant in the Premises or about the Project,
except for such substances as are typically found in similar premises used for general office purposes and are being used by Tenant in a safe manner and in accordance with all Laws. Without limiting the foregoing, Tenant shall not, without
Landlord’s prior consent, use, store, install, disturb, spill, remove, release or dispose of, within or about the Premises or any other portion of the Project, any asbestos-containing materials or any solid, liquid or gaseous material now or
subsequently considered toxic or hazardous under the provisions of 42 U.S.C. Section 9601 et seq. or any other applicable environmental Law. Tenant shall comply with all Laws pertaining to and governing the use of these materials by Tenant and
shall remain solely liable for the costs of abatement and removal. No burning candle or other open flame shall be ignited or kept by Tenant in the Premises or about the Project. 

12. Tenant shall not, without Landlord’s prior consent, use any method of heating or air conditioning other than that supplied by
Landlord or otherwise reasonably approved by Landlord. 
 13. Tenant shall not use or keep any foul or noxious gas or substance
in or on the Premises, or occupy or use the Premises in a manner offensive or objectionable to Landlord or other occupants of the Project by reason of noise, odors or vibrations, or interfere with other occupants or those having business therein,
whether by the use of any musical instrument, radio, CD player or otherwise. Tenant shall not throw anything out of doors, windows or skylights or down passageways. 
 14. Tenant shall not bring into or keep within the Project, the Building or the Premises any animals (other than service animals), birds, aquariums, or, except in areas designated by Landlord, bicycles or
other vehicles. 
 15. No cooking shall be done in the Premises, nor shall the Premises be used for lodging, for living quarters
or sleeping apartments, or for any improper, objectionable or immoral purposes. Notwithstanding the foregoing, Underwriters’ laboratory-approved equipment and microwave ovens may be used in the Premises for heating food and brewing coffee, tea,
hot chocolate and similar beverages for employees and invitees, provided that such use complies with all Laws. 
 16. The
Premises shall not be used for manufacturing or for the storage of merchandise except to the extent such storage may be incidental to the Permitted Use. Tenant shall not occupy the Premises as an office for a messenger-type operation or dispatch
office, public stenographer or typist, or for the manufacture or sale of liquor, narcotics or tobacco, or as a medical office, a barber or manicure shop, or an employment bureau, without Landlord’s prior consent. Tenant shall not engage or pay
any employees in the Premises except those actually working for Tenant in the Premises, nor advertise for laborers giving an address at the Premises. 
 17. Landlord may exclude from the Project any person who, in Landlord’s judgment, is intoxicated or under the influence of liquor or drugs, or who violates any of these Rules and Regulations.

 18. Tenant shall not loiter in or on the entrances, corridors, sidewalks, lobbies, courts, halls, stairways, elevators,
vestibules or any Common Areas for the purpose of smoking tobacco products or for any other purpose, nor in any way obstruct such areas, and shall use them only as a means of ingress and egress for the Premises. 

19. Tenant shall not waste electricity, water or air conditioning, shall cooperate with Landlord to ensure the most effective operation
of the Building’s heating and air conditioning system, and shall not attempt to adjust any controls. Tenant shall install and use in the Premises only ENERGY STAR rated equipment, where available. Tenant shall use recycled paper in the Premises
to the extent consistent with its business requirements. 
 20. Tenant shall store all its trash and garbage inside the
Premises. No material shall be placed in the trash or garbage receptacles if, under Law, it may not be disposed of in the ordinary and customary manner of disposing of trash and garbage in the vicinity of the Building. All trash, garbage and refuse
disposal shall be made only through entryways and elevators provided for such purposes at such times as Landlord shall designate. Tenant shall comply with Landlord’s recycling program, if any. 

  
 Exhibit D

 2 







 21. Tenant shall comply with all safety, fire protection and evacuation procedures and
regulations established by Landlord or any governmental agency. 
 22. Any persons employed by Tenant to do janitorial work
shall be subject to Landlord’s prior consent and, while in the Building and outside of the Premises, shall be subject to the control and direction of the Building manager (but not as an agent or employee of such manager or Landlord), and Tenant
shall be responsible for all acts of such persons. 
 23. No awning or other projection shall be attached to the outside walls
of the Building without Landlord’s prior consent. Other than Landlord’s Building-standard window coverings, no curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the
Premises. All electrical ceiling fixtures hung in the Premises or spaces along the perimeter of the Building must be fluorescent and/or of a quality, type, design and a warm white bulb color approved in advance by Landlord. Neither the interior nor
exterior of any windows shall be coated or otherwise sunscreened without Landlord’s prior consent. Tenant shall abide by Landlord’s regulations concerning the opening and closing of window coverings. 

24. Tenant shall not obstruct any sashes, sash doors, skylights, windows or doors that reflect or admit light or air into the halls,
passageways or other public places in the Building, nor shall Tenant place any bottles, parcels or other articles on the windowsills. 
 25. Tenant must comply with requests by Landlord concerning the informing of their employees of items of importance to the Landlord. 

26. Tenant must comply with the State of California “No-Smoking” law set forth in California Labor Code Section 6404.5 and
with any local “No-Smoking” ordinance that is not superseded by such law. 
 27. Tenant shall cooperate in any
reasonable safety or security program developed by Landlord or required by Law. 
 28. All office equipment of an electrical or
mechanical nature shall be placed by Tenant in the Premises in settings approved by Landlord, to absorb or prevent any vibration, noise or annoyance. 
 29. Tenant shall not use any hand trucks except those equipped with rubber tires and rubber side guards. 
 30. No auction, liquidation, fire sale, going-out-of-business or bankruptcy sale shall be conducted in the Premises without Landlord’s prior consent. 

31. Without Landlord’s prior consent, Tenant shall not use the name of the Project or Building or use pictures or illustrations of
the Project or Building in advertising or other publicity or for any purpose other than as the address of the business to be conducted by Tenant in the Premises. 
 Landlord may from time to time modify or supplement these Rules and Regulations in a manner that, in Landlord’s reasonable judgment, is appropriate for the management, safety, care and cleanliness of
the Premises, the Building, the Common Areas and the Project, for the preservation of good order therein, and for the convenience of other occupants and tenants thereof, provided that no changed or new rule and/or regulation shall materially and
adversely affect any of Tenant’s material rights under this Lease or unreasonably interfere with the conduct of Tenants business in the Premises. Landlord may waive any of these Rules and Regulations for the benefit of any tenant, but no such
waiver shall be construed as a waiver of such Rule and Regulation in favor of any other tenant nor prevent Landlord from thereafter enforcing such Rule and Regulation against any tenant. Landlord shall not discriminate against Tenant in
Landlord’s enforcement of the rules and regulations. The rules and regulations shall be generally applicable, and generally applied in the same manner, to all tenants of the Building. 

  
 Exhibit D

 3 







 EXHIBIT E 

10880 WILSHIRE BOULEVARD 
 JUDICIAL REFERENCE 
 IF THE JURY-WAIVER PROVISIONS OF
SECTION 25.8 OF THIS LEASE ARE NOT ENFORCEABLE UNDER CALIFORNIA LAW, THE PROVISIONS SET FORTH BELOW SHALL APPLY. 

It is the desire and intention of the parties to agree upon a mechanism and procedure under which controversies and disputes arising out
of this Lease or related to the Premises will be resolved in a prompt and expeditious manner. Accordingly, except with respect to actions for unlawful or forcible detainer or with respect to the prejudgment remedy of attachment, any action,
proceeding or counterclaim brought by either party hereto against the other (and/or against its officers, directors, employees, agents or subsidiaries or affiliated entities) on any matters arising out of or in any way connected with this Lease,
Tenant’s use or occupancy of the Premises and/or any claim of injury or damage, whether sounding in contract, tort, or otherwise, shall be heard and resolved by a referee under the provisions of the California Code of Civil Procedure, Sections
638 — 645.1, inclusive (as same may be amended, or any successor statute(s) thereto) (the “Referee Sections”). Any fee to initiate the judicial reference proceedings and all fees charged and costs incurred by the referee shall
be paid by the party initiating such procedure (except that if a reporter is requested by either party, then a reporter shall be present at all proceedings where requested and the fees of such reporter – except for copies ordered by the other
parties – shall be borne by the party requesting the reporter); provided however, that allocation of the costs and fees, including any initiation fee, of such proceeding shall be ultimately determined in accordance with Section 25.6
of this Lease. The venue of the proceedings shall be in the county in which the Premises is located. Within 10 days of receipt by any party of a request to resolve any dispute or controversy pursuant to this Exhibit E, the parties
shall agree upon a single referee who shall try all issues, whether of fact or law, and report a finding and judgment on such issues as required by the Referee Sections. If the parties are unable to agree upon a referee within such 10-day period,
then any party may thereafter file a lawsuit in the county in which the Premises is located for the purpose of appointment of a referee under the Referee Sections. If the referee is appointed by the court, the referee shall be a neutral and
impartial retired judge with substantial experience in the relevant matters to be determined, from Jams/Endispute, Inc., ADR Services, Inc. or a similar mediation/arbitration entity approved by each party in its sole and absolute discretion.
The proposed referee may be challenged by any party for any of the grounds listed in the Referee Sections. The referee shall have the power to decide all issues of fact and law and report his or her decision on such issues, and to issue all
recognized remedies available at law or in equity for any cause of action that is before the referee, including an award of attorneys’ fees and costs in accordance with this Lease. The referee shall not, however, have the power to award
punitive damages, nor any other damages that are not permitted by the express provisions of this Lease, and the parties waive any right to recover any such damages. The parties may conduct all discovery as provided in the California Code of Civil
Procedure, and the referee shall oversee discovery and may enforce all discovery orders in the same manner as any trial court judge, with rights to regulate discovery and to issue and enforce subpoenas, protective orders and other limitations on
discovery available under California Law. The reference proceeding shall be conducted in accordance with California Law (including the rules of evidence), and in all regards, the referee shall follow California Law applicable at the time of the
reference proceeding. The parties shall promptly and diligently cooperate with one another and the referee, and shall perform such acts as may be necessary to obtain a prompt and expeditious resolution of the dispute or controversy in accordance
with the terms of this Exhibit E. In this regard, the parties agree that the parties and the referee shall use best efforts to ensure that (a) discovery be conducted for a period no longer than 6 months from the date the
referee is appointed, excluding motions regarding discovery, and (b) a trial date be set within 9 months of the date the referee is appointed. In accordance with Section 644 of the California Code of Civil Procedure, the decision of
the referee upon the whole issue must stand as the decision of the court, and upon the filing of the statement of decision with the clerk of the court, or with the judge if there is no clerk, judgment may be entered thereon in the same manner as if
the action had been tried by the court. Any decision of the referee and/or judgment or other order entered thereon shall be appealable to the same extent and in the same manner that such decision, judgment, or order would be appealable if rendered
by a judge of the superior court in which venue is proper hereunder. The referee shall in his/her statement of decision set forth his/her findings of fact and conclusions of law. The parties intend this general reference agreement to be specifically
enforceable in accordance with the Code of Civil Procedure. Nothing in this Exhibit E shall prejudice the right of any party to obtain provisional relief or other equitable remedies from a court of competent jurisdiction as shall
otherwise be available under the Code of Civil Procedure and/or applicable court rules. 

  
 Exhibit E

 1 







 EXHIBIT F 

10880 WILSHIRE BOULEVARD 
 ADDITIONAL PROVISIONS 
  

	1.	Asbestos Notification. Tenant acknowledges that it has received the asbestos notification letter attached to this Lease as Exhibit G,
disclosing the existence of asbestos in the Building. Tenant agrees to comply with the California “Connelly Act” and other applicable laws, including by providing copies of Landlord’s asbestos notification letter to all of
Tenant’s “employees” and “owners”, as those terms are defined in the Connelly Act and other applicable laws. 

  

	2.	Premises Furniture. Landlord and Tenant acknowledge and agree that the prior tenant in the Premises surrendered the Premises with certain items of
furniture remaining in the Premises (the “Premises Furniture”). Landlord consents to Tenant’s use of the Premises Furniture during the Term. Tenant accepts such Premises Furniture for use during the Term in as-is, where-is
condition with no representations or warranties from Landlord as to title, quality, condition, merchantability or fitness for use; any such warranties being specifically excluded. Tenant shall maintain the Premises Furniture in good condition and
repair during the Term, at Tenant’s sole cost and expense, and upon expiration of the Term, Tenant shall have the right to purchase the Tenant Furniture for the sum of $1.00. 


 

	3.	Extension Option. 

  

	 	3.1.	Grant of Option; Conditions. Tenant shall have the right (the “Extension Option”) to extend the Term for one additional period of five
(5) years commencing on the day following the Expiration Date and ending on the fifth (5th) anniversary of the Expiration Date (the “Extension Term”), if: 


 

	 	A.	Not less than 10 nor more than 12 full calendar months before the Expiration Date, Tenant delivers written notice to Landlord (the “Extension Notice”)
electing to exercise the Extension Option and stating Tenant’s estimate of the Prevailing Market (defined in Section 3.5 below) rate for the Extension Term; 


 

	 	B.	Tenant is not in Default under the Lease beyond any applicable cure period when Tenant delivers the Extension Notice; 


 

	 	C.	Not more than 25% of the Premises is sublet when Tenant delivers the Extension Notice (except in connection with a Permitted Transfer); and 


 

	 	D.	The Lease has not been assigned (except in connection with a Permitted Transfer) before Tenant delivers the Extension Notice. 


 

	 	3.2.	Terms Applicable to Extension Term. 

  

	 	A.	During the Extension Term, (a) the Base Rent rate per rentable square foot shall be equal to the Prevailing Market rate per rentable square foot; (b) Base
Rent shall increase, if at all, in accordance with the increases assumed in the determination of Prevailing Market rate; and (c) Base Rent shall be payable in monthly installments in accordance with the terms and conditions of the Lease.


  

	 	B.	During the Extension Term Tenant shall pay Tenant’s Share of Expenses and Taxes for the Premises in accordance with the Lease. Tenant’s Base Year shall be
reset to be the calendar year in which the applicable Extension Term commences. 

  

	 	3.3.	Procedure for Determining Prevailing Market. 

  

	 	A.	 Initial Procedure. Within 30 days after receiving the Extension Notice, Landlord shall give Tenant either (i) written notice
(“Landlord’s Binding Notice”) accepting Tenant’s estimate of the Prevailing Market rate for the Extension Term stated in the Extension Notice, or (ii) written notice (“Landlord’s Rejection
Notice”) rejecting such estimate and stating Landlord’s estimate of the Prevailing Market rate for the Extension Term. If Landlord gives Tenant a Landlord’s Rejection Notice, Tenant, within 15 days thereafter, shall give
Landlord either (i) written notice (“Tenant’s Binding Notice”) accepting Landlord’s estimate of the Prevailing Market rate for the Extension Term stated in such Landlord’s




  
 Exhibit F

 1 








	 	
Rejection Notice, or (ii) written notice (“Tenant’s Rejection Notice”) rejecting such estimate. If Tenant gives Landlord a Tenant’s Rejection Notice, Landlord and
Tenant shall work together in good faith to agree in writing upon the Prevailing Market rate for the Extension Term. If, within 30 days after delivery of a Tenant’s Rejection Notice, the parties fail to agree in writing upon the Prevailing
Market rate, the provisions of Section 3.3.B below shall apply. 

  

	 	B.	Dispute Resolution Procedure. 

  

	 	1.	If, within 30 days after delivery of a Tenant’s Rejection Notice, the parties fail to agree in writing upon the Prevailing Market rate, Landlord and Tenant,
within five (5) days thereafter, shall each simultaneously submit to the other, in a sealed envelope, its good faith estimate of the Prevailing Market rate for the Extension Term (collectively, the “Estimates”). Within
seven (7) days after the exchange of Estimates, Landlord and Tenant shall each select an appraiser to determine which of the two Estimates most closely reflects the Prevailing Market rate for the Extension Term. Each appraiser so selected shall
be certified as an MAI appraiser or as an ASA appraiser and shall have had at least five (5) years’ experience within the previous 10 years as a real estate appraiser working in Los Angeles, California, with working knowledge of current
rental rates and leasing practices relating to buildings similar to the Building and shall not be then employed by such selecting party, or have been in the employment of such selecting party within the last 5 years. For purposes hereof, an
“MAI” appraiser means an individual who holds an MAI designation conferred by, and is an independent member of, the American Institute of Real Estate Appraisers (or its successor organization, or in the event there is no successor
organization, the organization and designation most similar), and an “ASA” appraiser means an individual who holds the Senior Member designation conferred by, and is an independent member of, the American Society of Appraisers (or
its successor organization, or, in the event there is no successor organization, the organization and designation most similar). 

  

	 	2.	If each party selects an appraiser in accordance with Section 3.B.1 above, the parties shall cause their respective appraisers to work together in good
faith to agree upon which of the two Estimates most closely reflects the Prevailing Market rate for the Extension Term. The Estimate, if any, so agreed upon by such appraisers shall be final and binding on both parties as the Prevailing Market rate
for the Extension Term and may be entered in a court of competent jurisdiction. If the appraisers fail to reach such agreement within 20 days after their selection, then, within 10 days after the expiration of such 20-day period, the
parties shall instruct the appraisers to select a third appraiser meeting the above criteria (and if the appraisers fail to agree upon such third appraiser within 10 days after being so instructed, either party may cause a court of competent
jurisdiction to select such third appraiser). Promptly upon selection of such third appraiser, the parties shall instruct such appraiser (or, if only one of the parties has selected an appraiser within the 7-day period described above, then promptly
after the expiration of such 7-day period the parties shall instruct such appraiser) to determine, as soon as practicable but in any case within 14 days after his selection, which of the two Estimates most closely reflects the Prevailing Market
rate. Such determination by such appraiser (the “Final Appraiser”) shall be final and binding on both parties as the Prevailing Market rate for the Extension Term and may be entered in a court of competent jurisdiction. If the Final
Appraiser believes that expert advice would materially assist him, he may retain one or more qualified persons to provide such expert advice. The parties shall share equally in the costs of the Final Appraiser and of any experts retained by the
Final Appraiser. Any fees of any other appraiser, counsel or expert engaged by Landlord or Tenant shall be borne by the party retaining such appraiser, counsel or expert. 


 

	 	C.	 If the Prevailing Market rate has not been determined by the commencement date of the Extension Term, Tenant shall pay Base Rent for the Extension Term
upon the terms and conditions in effect during the last month ending on or before the Extended Expiration Date until such time as the Prevailing Market rate has 



  
 Exhibit F

 2 








	 	
been determined. Upon such determination, the Base Rent for the Extension Term shall be retroactively adjusted. If such adjustment results in an under- or overpayment of Base Rent by Tenant,
Tenant shall pay Landlord the amount of such underpayment, or receive a credit in the amount of such overpayment, with or against the next Base Rent due under the Lease. 


 

	 	3.4.	Extension Amendment. If Tenant is entitled to and properly exercises its Extension Option, and if the Prevailing Market rate for the Extension Term is
determined in accordance with Section 3.3 above, Landlord, within a reasonable time thereafter, shall prepare and deliver to Tenant an amendment (the “Extension Amendment”) reflecting changes in the Base Rent, the term
of the Lease, the expiration date of the Lease, and other appropriate terms, and Tenant shall execute and return the Extension Amendment to Landlord within 15 days after receiving it. Notwithstanding the foregoing, upon determination of the
Prevailing Market rate for the Extension Term in accordance with Section 3.3 above, an otherwise valid exercise of the Extension Option shall be fully effective whether or not the Extension Amendment is executed.


  

	 	3.5.	Definition of Prevailing Market. For purposes of this Extension Option, “Prevailing Market” shall mean the arms-length, fair-market,
initial annual rental rate per rentable square foot under extension and renewal leases and amendments entered into on or about the date on which the Prevailing Market is being determined hereunder for space comparable to the Premises in the Building
and Project. The determination of Prevailing Market shall take into account any material economic differences between the terms of the Lease and any comparison lease or amendment, such as rent abatements, construction costs and other concessions,
and the manner, if any, in which the landlord under any such lease is reimbursed for operating expenses and taxes. The determination of Prevailing Market shall also take into consideration any reasonably anticipated changes in the Prevailing Market
rate from the time such Prevailing Market rate is being determined and the time such Prevailing Market rate will become effective under the Lease.. 

  

	4.	Acceleration Option. 

  

	 	4.1	Tenant shall have the right (the “Acceleration Option”) to accelerate the Expiration Date, with respect to the entire Premises only, from the scheduled
Expiration Date to the last day of the 60th full calendar month following the Commencement Date (the “Accelerated Expiration Date”) if: 

  

	 	A.	Tenant delivers to Landlord, at least 270 days before the Accelerated Expiration Date, a written notice (the “Acceleration Notice”) exercising the
Acceleration Option. 

  

	 	B.	Tenant is not in default under the Lease when Tenant delivers the Acceleration Notice to Landlord; 


 

	 	C.	No part of the Premises is sublet past the Accelerated Expiration Date when Tenant delivers the Acceleration Notice to Landlord (unless such sublease will automatically
terminate as of the Accelerated Expiration Date in accordance with its terms and conditions); and 

  

	 	D.	The Lease has not been assigned (other than pursuant to a Permitted Transfer) before Tenant delivers the Acceleration Notice to Landlord.


  

	 	4.2	If Tenant validly exercises the Acceleration Option, then (i) notwithstanding any contrary provision of the Lease, but subject to the terms of this Section 4,
the term of the Lease shall expire, with respect to the entire Premises, on the Accelerated Expiration Date with the same force and effect as if such term were, by the provisions of the Lease, fixed to expire on the Accelerated Expiration Date; and
(ii) without limiting the foregoing: 

  

	 	A.	The portion of the Base Rent schedule set forth in Section 1.4 of the Lease that applies during the period following the Accelerated Expiration Date shall be
deleted from the Lease; and 

  

	 	B.	Tenant shall surrender the Premises to Landlord in accordance with the terms of the Lease on or before the Accelerated Expiration Date; and 


  
 Exhibit F

 3 








	 	C.	Tenant shall remain liable for all Rent and other amounts payable under the Lease for the period up to and to and including the Accelerated Expiration Date, even though
billings for such amounts may occur after the Accelerated Expiration Date; and 

  

	 	D.	Tenant’s restoration obligations shall be as set forth in the Lease; and 


 

	 	E.	If Tenant fails to surrender any portion of the Premises on or before the Accelerated Expiration Date, Tenant’s tenancy shall be subject to Section 16 of the
Lease; and 

  

	 	F.	Any other rights or obligations of Landlord or Tenant under the Lease that, in the absence of the Acceleration, would have survived the scheduled Expiration Date shall
survive the Accelerated Expiration Date. 

  

	 	4.3	If Tenant exercises the Acceleration Option, then Tenant shall pay to Landlord, as a fee in connection with the acceleration of the Expiration Date and not as a
penalty, an amount (the “Acceleration Fee”) equal to the sum of the portion of each of the following amounts that remains unamortized (as determined using an interest rate of 8% per annum) as of the Accelerated Expiration
Date: the Abated Base Rent, the Allowance and any internal or external brokerage commissions paid by Landlord in connection with the Lease. At any time after Landlord receives the Acceleration Notice, Landlord may deliver to Tenant an invoice
specifying the amount of the Acceleration Fee, whereupon Tenant shall pay the Acceleration Fee to Landlord within 15 days after receiving such invoice. 


 

	 	4.4	If, after delivering an Acceleration Notice to Landlord, Tenant defaults under the Lease (including, without limitation, by failing to timely pay the Acceleration Fee),
Landlord, at its option, may (i) declare Tenant’s exercise of the Acceleration Option to be null and void (in which event Landlord shall return to Tenant any Acceleration Fee received from Tenant, but only after applying it against any
past due Rent, or (ii) continue to honor Tenant’s exercise of its Acceleration Option in accordance with the terms hereof. 

  

	 	45	If Tenant validly exercises the Acceleration Option, Landlord shall prepare an amendment (the “Acceleration Amendment”) reflecting the same. Landlord
shall deliver the Acceleration Amendment to Tenant within a reasonable time after receiving the Acceleration Notice, and Tenant shall execute and return the Acceleration Amendment to Landlord within 15 days after receiving it. At
Landlord’s option, an otherwise valid exercise of the Acceleration Option shall be fully effective whether or not the Acceleration Amendment is executed. 


 

	 	4.6	Notwithstanding any contrary provision of the Lease, from and after the date Tenant delivers an Acceleration Notice to Landlord, (a) any unexercised right or
option of Tenant to renew or extend the Term or to expand the Premises (whether in the form of an expansion option, right of first offer or refusal, or any other similar right), and any outstanding tenant improvement allowance or other allowance not
claimed and properly used by Tenant in accordance with the Lease as of such date, shall immediately be deemed terminated and no longer available or of any further force or effect, and (b) Tenant shall not sublease all or any portion of the
Premises for any period following the Accelerated Expiration Date. 

  

	5.	TEMPORARY SPACE. 

  

	 	5.1.	 During the period beginning on: (i) the later of the full and final execution of this Lease by Landlord and Tenant (including delivery by Tenant
of any Security Deposit, prepaid rental and certificates of insurance covering the Premises and Temporary Space during the Temporary Space Term), and ending on (ii) the Commencement Date (such period being referred to herein as the
“Temporary Space Term”), Landlord shall allow Tenant to use approximately 3,657 rentable square feet of space known as Suite No. 530 located on the fifth (5th) floor of the Building as shown on Exhibit H of this Lease (the “Temporary Space”) for
the Permitted Use. During the Temporary Space Term, the Temporary Space shall be deemed the “Premises” for purposes of Article 10 



  
 Exhibit F

 4 








	 	
(Indemnification; Insurance) of the Lease. Such Temporary Space shall be accepted by Tenant in its “as-is” condition and configuration, it being agreed that Landlord shall be under no
obligation to perform any work in the Temporary Space or to incur any costs in connection with Tenant’s move in, move out or occupancy of the Temporary Space. Tenant acknowledges that it shall be entitled to use and occupy the Temporary Space
at its sole cost, expense and risk. Tenant shall not construct any improvements or make any alterations of any type to the Temporary Space without the prior written consent of Landlord. All costs in connection with making the Temporary Space ready
for occupancy by Tenant shall be the sole responsibility of Tenant. 

  

	 	5.2.	The Temporary Space shall be subject to all the terms and conditions of the Lease except as expressly modified herein and except that (i) Tenant shall not be
entitled to receive any allowances or other financial concession in connection with the Temporary Space which was granted with respect to the Premises unless such concessions are expressly provided for herein with respect to the Temporary Space,
(ii) the Temporary Space shall not be subject to any renewal or expansion rights of Tenant under the Lease, (iii) Tenant shall not be required to pay Base Rent for the Temporary Space during the portion of the Temporary Space Term
beginning on the full and final execution of the Lease and ending on December 14, 2011, and (iv) Tenant shall not be required to pay Tenant’s Share of Expenses and Taxes for the Temporary Space during the Temporary Space Term. In the
event that the Temporary Space Term does not expire on or before December 14, 2011, during the period beginning on December 15, 2011 and ending on the last day of the Temporary Space Term, Tenant shall pay Base Rent for the Temporary Space
at the rate of $372.71 per day. 

  

	 	5.3	Upon termination of the Temporary Space Term, Tenant shall vacate the Temporary Space and deliver the same to Landlord in the same condition that the Temporary Space
was delivered to Tenant, ordinary wear and tear and damage by Casualty excepted. At the expiration or earlier termination of the Temporary Space Term, Tenant shall remove all debris, all items of Tenant’s personalty, and any trade fixtures of
Tenant from the Temporary Space. Tenant shall be fully liable for all damage Tenant or Tenant’s agents, employees, contractors, or subcontractors cause to the Temporary Space. 


 

	 	5.4.	Tenant shall have no right to hold over or otherwise occupy the Temporary Space at any time following the expiration or earlier termination of the Temporary Space Term,
and in the event of such holdover, Landlord shall immediately be entitled to institute dispossessory proceedings to recover possession of the Temporary Space, without first providing notice thereof to Tenant. In the event of holding over by Tenant
after expiration or termination of the Temporary Space Term without the written authorization of Landlord, Tenant shall pay, for such holding over, the sum of $5.00 per rentable square foot per month for each month or partial month of holdover,
plus all actual and proximate (but not consequential, punitive or other special) damages that Landlord incurs as a result of the Tenant’s hold over. During any such holdover, Tenant’s occupancy of the Temporary Space shall be deemed
that of a tenant at sufferance, and in no event, either during the Temporary Space Term or during any holdover by Tenant, shall Tenant be determined to be a tenant-at-will under applicable law. While Tenant is occupying the Temporary
Space, Landlord or Landlord’s authorized agents shall be entitled to enter the Temporary Space, upon reasonable notice, to display the Temporary Space to prospective tenants. 


 

	6.	LETTER OF CREDIT. 

  

	 	6.1.	 General Provisions. Within five (5) business days after Tenant’s execution of this Lease, Tenant shall deliver to Landlord, as
collateral for the full performance by Tenant of all of its obligations under this Lease and for all losses and damages Landlord may suffer as a result of Tenant’s failure to comply with one or more provisions of this Lease, including,
but not limited to, any post lease termination damages under section 1951.2 of the California Civil Code, a standby, unconditional, irrevocable, transferable letter of credit (the “Letter of Credit”) in the form of Exhibit
I hereto and containing the terms required herein, in the face amount of $1,000,000.00 (the “Letter of Credit Amount”), naming Landlord as beneficiary, issued (or confirmed) by Wells Fargo N.A., or another
financial institution reasonably approved by Landlord, permitting multiple and partial draws thereon, and otherwise in form reasonably acceptable to Landlord. Tenant shall cause the Letter of Credit to be continuously maintained in effect (whether
through replacement, renewal or extension) in the Letter of Credit Amount through the date (the “Final LC Expiration Date”) that is 60 days after the expiration date of the Term or any renewal




  
 Exhibit F

 5 








	 	
Term or any earlier termination of this Lease (including an early termination by reason of Tenant’s exercise of its Acceleration Option). If the Letter of Credit held by Landlord expires
earlier than the Final LC Expiration Date (whether by reason of a stated expiration date or a notice of termination or non-renewal given by the issuing bank), Tenant shall deliver a new Letter of Credit or certificate of renewal or extension (a
“Renewal or Replacement LC”) to Landlord not later than 30 days prior to the expiration date of the Letter of Credit then held by Landlord. Any Renewal or Replacement LC shall comply with all of the provisions of this
Section 6.1, shall be irrevocable, transferable and shall remain in effect (or be automatically renewable) through the Final LC Expiration Date upon the same terms as the expiring Letter of Credit or such other terms as may be acceptable to
Landlord in its sole discretion. 

  

	 	6.2.	Drawings under Letter of Credit. Upon the occurrence of a Default by Tenant’s or the occurrence of an event which with notice and passage of time, or both,
would constitute a default but for the fact that Landlord is barred from providing notice thereof to Tenant by reason of any applicable debtor relief laws (herein, a “Deemed Default”) , or as otherwise specifically agreed by
Landlord and Tenant pursuant to this Lease or any amendment hereof, Landlord may, without prejudice to any other remedy provided in this Lease or by Law, draw on the Letter of Credit and use all or part of the proceeds to (a) satisfy any
amounts due to Landlord from Tenant, and (b) satisfy any other damage, injury, expense or liability caused by Tenant’s Default or Deemed Default. In addition, if Tenant fails to furnish a Renewal or Replacement LC complying with all of the
provisions of this Section 6 at least 30 days prior to the stated expiration date of the Letter of Credit then held by Landlord, Landlord may draw upon such Letter of Credit and hold the proceeds thereof (and such proceeds need not be
segregated) in accordance with the terms of this Section 6 (the “LC Proceeds Account”). 

  

	 	6.3.	Use of Proceeds by Landlord. If Landlord is entitled draw on the Letter of Credit pursuant to the provisions of this Section 6, then the proceeds of the
Letter of Credit shall constitute Landlord’s sole and separate property (and not Tenant’s property or the property of Tenant’s bankruptcy estate) and Landlord may immediately upon any draw (and without notice to Tenant) apply or
offset the proceeds of the Letter of Credit: (a) against any Rent payable by Tenant under this Lease that is not paid when due; (b) against all losses and damages that Landlord has suffered or that Landlord reasonably estimates that it may
suffer as a result of Tenant’s Default or Deemed Default, including any damages arising under section 1951.2 of the California Civil Code following termination of the Lease; (c) against any costs incurred by Landlord in connection with the
Lease (including attorneys’ fees); and (d) against any other amount that Landlord may spend or become obligated to spend by reason of Tenant’s Default or Deemed Default. Provided Tenant has performed all of its obligations under this
Lease, Landlord agrees to pay to Tenant within 45 days after the Final LC Expiration Date the amount of any proceeds of the Letter of Credit received by Landlord and not applied as allowed above; provided, that if prior to the Final LC Expiration
Date a voluntary petition is filed by Tenant or any Guarantor, or an involuntary petition is filed against Tenant or any Guarantor by any of Tenant’s or Guarantor’s creditors, under the Federal Bankruptcy Code, then Landlord shall not be
obligated to make such payment in the amount of the unused Letter of Credit proceeds until either all preference issues relating to payments under this Lease have been resolved in such bankruptcy or reorganization case or such bankruptcy or
reorganization case has been dismissed, in each case pursuant to a final court order not subject to appeal or any stay pending appeal. 

  

	 	6.4.	Additional Covenants of Tenant. If, as result of any application or use by Landlord of all or any part of the Letter of Credit, the amount of the Letter of
Credit shall be less than the Letter of Credit Amount, Tenant shall, within 5 days thereafter, provide Landlord with additional letter(s) of credit in an amount equal to the deficiency (or a replacement letter of credit in the total Letter of Credit
Amount), and any such additional (or replacement) letter of credit shall comply with all of the provisions of this Section 6, and if Tenant fails to comply with the foregoing, notwithstanding anything to the contrary contained in this Lease,
the same shall constitute an incurable Default by Tenant. Tenant further covenants and warrants that it will neither assign nor encumber the Letter of Credit or any part thereof and that neither Landlord nor its successors or assigns will be bound
by any such assignment, encumbrance, attempted assignment or attempted encumbrance. 

  

	 	6.5.	 Nature of Letter of Credit. Landlord and Tenant (a) acknowledge and agree that in no event or circumstance shall the Letter of Credit or
any renewal thereof or substitute therefor or any proceeds thereof (including the LC Proceeds Account) be deemed to be or treated as a “security deposit” under any Law applicable to security deposits in the commercial context including
Section 1950.7 of the California Civil Code, as such 



  
 Exhibit F

 6 








	 	
section now exist or as may be hereafter amended or succeeded (“Security Deposit Laws”), (b) acknowledge and agree that the Letter of Credit (including any renewal thereof
or substitute therefor or any proceeds thereof) is not intended to serve as a security deposit, and the Security Deposit Laws shall have no applicability or relevancy thereto, and (c) waive any and all rights, duties and obligations either
party may now or, in the future, will have relating to or arising from the Security Deposit Laws. Tenant hereby waives the provisions of Section 1950.7 of the California Civil Code and all other provisions of Law, now or hereafter in effect,
which (i) establish the time frame by which Landlord must refund a security deposit under a lease, and/or (ii) provide that Landlord may claim from the security deposit only those sums reasonably necessary to remedy Defaults in the payment
of rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums specified above in this Section 6 and/or those sums reasonably necessary to compensate Landlord for any loss
or damage caused by Tenant’s breach of this Lease or the acts or omission of Tenant or any other Tenant Related Parties, including any damages Landlord suffers following termination of the Lease. 


 

	 	6.6.	 Reduction in Letter of Credit Amount. Provided that, during the 12 month period immediately preceding the effective date of any reduction
of the Letter of Credit, no Default has occurred under this Lease which was not cured by Tenant within any applicable notice and cure periods (the “LC Reduction Conditions”), Tenant may reduce the Letter of Credit Amount so that the
reduced Letter of Credit Amounts will be as follows: (a) $857,143.00 effective as of the first (1st) anniversary of the Commencement Date; (b) $714,286.00 effective as of the second (2nd) anniversary of the Commencement Date; (c) $517,429.00 effective as of the third (3rd) anniversary of the Commencement Date; (d) $428,572.00
effective as of the fourth (4th) anniversary of the
Commencement Date, (e) $285,715.00 effective as of the fifth (5th) anniversary of the Commencement Date and (f) $142,858.00 effective as of the sixth (6th) anniversary of the Commencement Date. If Tenant is not entitled to reduce the Letter of Credit Amount as of a
particular reduction effective date due to Tenant’s failure to satisfy the LC Reduction Conditions described above, then any subsequent reduction(s) Tenant is entitled to hereunder shall be reduced by the amount of the reduction Tenant would
have been entitled to had Tenant satisfied the LC Reduction Conditions necessary for such earlier reduction. Notwithstanding anything to the contrary contained herein, if Tenant has been in Default under this Lease at any time prior to the effective
date of any reduction of the Letter of Credit Amount and Tenant has failed to cure such Default within any applicable notice and cure period, then Tenant shall have no further right to reduce the Letter of Credit Amount as described herein. Any
reduction in the Letter of Credit Amount shall be accomplished by Tenant providing Landlord with a substitute letter of credit in the reduced amount or an amendment to the existing Letter of Credit reflecting the reduced amount..




  
 Exhibit F

 7 







 EXHIBIT G 

10880 WILSHIRE BOULEVARD 
 ASBESTOS NOTIFICATION 
 Asbestos-containing materials
(“ACMs”) were historically commonly used in the construction of commercial buildings across the country. ACMs were commonly used because of their beneficial qualities; ACMs are fire-resistant and provide good noise and temperature
insulation. 
 Some common types of ACMs include surfacing materials (such as spray-on fireproofing, stucco, plaster and
textured paint), flooring materials (such as vinyl floor tile and vinyl floor sheeting) and their associated mastics, carpet mastic, thermal system insulation (such as pipe or duct wrap, boiler wrap and cooling tower insulation), roofing materials,
drywall, drywall joint tape and drywall joint compound, acoustic ceiling tiles, transite board, base cove and associated mastic, caulking, window glazing and fire doors. These materials are not required under law to be removed from any building
(except prior to demolition and certain renovation projects). Moreover, ACMs generally are not thought to present a threat to human health unless they cause a release of asbestos fibers into the air, which does not typically occur unless
(1) the ACMs are in a deteriorated condition, or (2) the ACMs have been significantly disturbed (such as through abrasive cleaning, or maintenance or renovation activities). 

It is possible that some of the various types of ACMs noted above (or other types) are present at various locations in the Building.
Anyone who finds any such materials in the Building should assume them to contain asbestos unless those materials are properly tested and found to be otherwise. In addition, under applicable Law, certain of these materials are required to be
presumed to contain asbestos in the Building because the Building was built prior to 1981 (these materials are typically referred to as “Presumed Asbestos Containing Materials” or “PACM”). PACM consists of thermal
system insulation and surfacing material found in buildings constructed prior to 1981, and asphalt or vinyl flooring installed prior to 1981. If any thermal system insulation, asphalt or vinyl flooring or surfacing materials are found to be present
in the Building, such materials must be considered PACM unless properly tested and found otherwise. In addition, Landlord has identified the presence of certain ACMs in the Building. For information about the specific types and locations of these
identified ACMs, please contact the Property Manager. The Property Manager maintains records of the Building’s asbestos information including any Building asbestos surveys, sampling and abatement reports. This information is maintained as part
of Landlord’s asbestos Operations and Maintenance Plan (“O&M Plan”). 
 The O&M Plan is designed
to minimize the potential of any harmful asbestos exposure to any person in the Building. Because Landlord is not a physician, scientist or industrial hygienist, Landlord has no special knowledge of the health impact of exposure to asbestos.
Therefore, Landlord hired an independent environmental consulting firm to prepare the Building’s O&M Plan. The O&M Plan includes a schedule of actions to be taken in order to (1) maintain any building ACMs in good condition, and
(2) to prevent any significant disturbance of such ACMs. Appropriate Landlord personnel receive regular periodic training on how to properly administer the O&M Plan. 
 The O&M Plan describes the risks associated with asbestos exposure and how to prevent such exposure. The O&M Plan describes those risks, in general, as follows: asbestos is not a significant
health concern unless asbestos fibers are released and inhaled. If inhaled, asbestos fibers can accumulate in the lungs and, as exposure increases, the risk of disease (such as asbestosis and cancer) increases. However, measures to minimize exposure
and consequently minimize the accumulation of fibers, reduce the risk of adverse health effects. 
 The O&M Plan also
describes a number of activities which should be avoided in order to prevent a release of asbestos fibers. In particular, some of the activities which may present a health risk (because those activities may cause an airborne release of asbestos
fibers) include moving, drilling, boring or otherwise disturbing ACMs. Consequently, such activities should not be attempted by any person not qualified to handle ACMs. In other words, the approval of Building management must be obtained prior to
engaging in any such activities. Please contact the Property Manager for more information in this regard. A copy of the written O&M Plan for the Building is located in the Building Management Office and, upon your request, will be made available
to tenants for you to review and copy during Building Service Hours. 
 Because of the presence of ACM in the Building, Landlord
is also providing the following warning, which is commonly known as a California Proposition 65 warning: 
 WARNING: This Building contains
asbestos, a chemical known to the State of California to cause cancer. 

  
 Exhibit G

 1 







 Please contact the Property Manager with any questions regarding the contents of this
Exhibit. 

  
 Exhibit G

 2 







 EXHIBIT H 

OUTLINE AND LOCATION OF TEMPORARY SPACE 
 



 

  
 Exhibit H

 1 







 EXHIBIT I 

FORM OF LETTER OF CREDIT 
  

 
 [Name of
Financial Institution] 
  

			
		 	Irrevocable Standby
		 	 Letter of Credit

		 	 No.
                                    

		 	 Issuance Date:
                  

		 	 Expiration Date:
              

		 	 Applicant:
                        



 Beneficiary 
 CA-10880 WILSHIRE LIMITED PARTNERSHIP, a Delaware limited partnership 
 Equity Office 

Two North Riverside Plaza, Suite 2100 
 Chicago,
Illinois 60606 
 Attention: Treasury Department. 
 A copy of any notices 
 and amendments should be sent to: 

CA-10880 Wilshire Limited Partnership 
 c/o
Equity Office 
 10880 Wilshire Boulevard 
 Suite 1010 
 Los Angeles, CA 90024 
 Attention: Property Manager 
 Ladies/Gentlemen: 

We hereby establish our Irrevocable Standby Letter of Credit in your favor for the account of the above referenced Applicant in the
amount of                  U.S. Dollars ($                ) available
for payment at sight by your draft drawn on us when accompanied by the following documents: 
  

	1.	An original copy of this Irrevocable Standby Letter of Credit. 

  

	2.	Beneficiary’s dated statement purportedly signed by an authorized signatory or agent reading: “This draw in the amount of
                 U.S. Dollars ($                ) under your
Irrevocable Standby Letter of Credit No.                      represents funds due and owing to us pursuant to the terms of that certain lease
by and between                                 , as landlord, and
                                , as tenant, and/or any amendment to the lease or
any other agreement between such parties related to the lease.” 

 It is a condition of this Irrevocable
Standby Letter of Credit that it will be considered automatically renewed for a one year period upon the expiration date set forth above and upon each anniversary of such date, unless at least 30 days prior to such expiration date or applicable
anniversary thereof, we notify you in writing, by certified mail return receipt requested or by recognized overnight courier service at the addresses set forth above, that we elect not to so renew this Irrevocable Standby Letter of Credit. In
addition to the foregoing, we understand and agree that you shall be entitled to draw upon this Irrevocable Standby Letter of Credit in accordance with 1 and 2 above in the event that we elect not to renew this Irrevocable Standby Letter of Credit
and, in addition, you provide us with a dated statement purportedly signed by an authorized signatory or agent of Beneficiary stating that the Applicant has failed to provide you with an acceptable substitute irrevocable standby letter of credit in
accordance with the terms of the above referenced lease. We further acknowledge and agree that: (a) upon receipt of the documentation required herein, we will honor your draws against this Irrevocable Standby Letter of Credit without inquiry
into the accuracy of Beneficiary’s signed statement and regardless of whether Applicant disputes the content of such statement; (b) this Irrevocable Standby Letter of Credit shall permit partial draws and, in the event you elect to draw
upon less than the full stated 

  
 Exhibit I

 1 







 
amount hereof, the stated amount of this Irrevocable Standby Letter of Credit shall be automatically reduced by the amount of such partial draw; and (c) you shall be entitled to transfer
your interest in this Irrevocable Standby Letter of Credit from time to time and more than one time without our approval and without charge. In the event of a transfer, we reserve the right to require reasonable evidence of such transfer as a
condition to any draw hereunder. 
 This Irrevocable Standby Letter of Credit is subject to the International Standby Practices
(ISP98) ICC Publication No. 590. 
 We hereby engage with you to honor drafts and documents drawn under and in compliance
with the terms of this Irrevocable Standby Letter of Credit. 
 All communications to us with respect to this Irrevocable
Standby Letter of Credit must be addressed to our office located at
                                        
to the attention of
                                        .

  

	
	
	Very truly yours,
	
	  

	
	 [name]

	
	 [title}




  
 Exhibit I

 2