EXHIBIT 10.33

 

LEASE AGREEMENT

 

THIS LEASE AGREEMENT (“this Lease”) is made as of this 6th day of February, 2013, between ARE-1500 EAST GUDE, LLC, a Delaware limited liability company (“Landlord”), and SUPERNUS PHARMACEUTICALS, INC., a Delaware corporation (“Tenant”).

 

BASIC LEASE PROVISIONS

 

Address:                                                 Suite 100, 1500 East Gude Drive, Rockville, Maryland 20850

 

Premises:                                             That portion of the Project, containing approximately 11,900 rentable square feet, as determined by Landlord, as shown as the cross-hatched area on Exhibit A.

 

Project:                                                      The real property on which the building (“Building”) in which the Premises are located, together with all improvements thereon and appurtenances thereto as described on Exhibit B.

 

	
Base   Rent: $10,908.33, per month
    	
Rentable   Area of Premises: 11,900 sq. ft.
    
	
 
    	
 
    
	
Rentable   Area of Project: 45,989 sq. ft. 
    	
Tenant’s   Share of Operating Expenses: 25.88%
    
	
 
    	
 
    
	
Security   Deposit: $0 
    	
Target   Commencement Date: March 1, 2013
    
	
 
    	
 
    
	
Rent   Adjustment Percentage: 2%
    	
 
    
	
 
    	
 
    
	
Base Term:  Beginning   on the Commencement Date and ending on April 30, 2018.
    
	
 
    	
 
    
	
Permitted Use:  office and related uses consistent with the   character of the Project and otherwise in compliance with the provisions of Section 7   hereof.
    
	
 
    	
 
    
	
Address   for Rent Payment:
    	
Landlord’s   Notice Address:
    
	
For   check payments remit to:
    	
385   E. Colorado Blvd., Suite 299
    
	
 
    	
Pasadena,   California 91101
    
	
ARE-1500 East Gude, LLC
    	
Attention:   Corporate Secretary
    
	
P.O. Box 62318
    	
 
    
	
Baltimore, MD 21264-62318
    	
 
    
	
 
    	
 
    
	
For   overnight courier remit to:
    	
 
    
	
 
    	
 
    
	
ARE-1500 East Gude, LLC
    	
 
    
	
M &T Bank
    	
 
    
	
Attn: Box 62318
    	
 
    
	
Baltimore, MD 21230
    	
 
    
	
 
    	
 
    
	
Tenant’s   Notice Address:
    	
 
    
	
1550   East Gude Drive
    	
 
    
	
Rockville,   Maryland 20850
    	
 
    
	
Attention:   Executive Director
    	
 
    
	
Compliance   and Facilities
    	
 
    
	
 
    	
 
    
	
The following Exhibits and Addenda are attached   hereto and incorporated herein by this reference:
    
	
 
    	
 
    
	
[X]   EXHIBIT A - PREMISES DESCRIPTION
    	
[X]   EXHIBIT B - DESCRIPTION OF PROJECT
    
	
 
    	
 
    
	
 
    	
Copyright   © 2007, Alexandria Real Estate Equities, Inc. ALL
    
	
 
    	
RIGHTS   RESERVED. Confidential and Proprietary - Do Not
    
	
 
    	
Copy   or Distribute. Alexandria and the Alexandria Logo are
    
	
ALEXANDRIA
    	
 
    	
registered   trademarks of Alexandria Real Estate Equities, Inc.
    
			


 











 

	
[X]   EXHIBIT C - WORK LETTER
    	
[X]   EXHIBIT D - COMMENCEMENT DATE
    
	
[X]   EXHIBIT E - RULES AND REGULATIONS
    	
[X]   EXHIBIT F - TENANT’S PERSONAL PROPERTY
    


 

1.                                      Lease of Premises. Upon and subject to all of the terms and conditions hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. The portions of the Project which are for the non-exclusive use of tenants of the Project are collectively referred to herein as the “Common Areas.” Landlord reserves the right to modify Common Areas, provided that such modifications do not materially adversely affect Tenant’s use of the Premises for the Permitted Use.

 

2.                                      Delivery; Acceptance of Premises; Commencement Date. Landlord shall use reasonable efforts to make the Premises available to Tenant for Tenant’s Work under the Work Letter within 5 days of full execution of this Lease and Tenant’s delivery of evidence of the insurance required hereby and by the Work Letter (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 60 days of the Target Commencement Date for any reason other than Force Majeure Delays, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either, neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, “Tenant’s Work” has the meaning set forth in the Work Letter and “Force Majeure Delays” means delays arising by reason of any Force Majeure (as defined in Section 34). If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.

 

The “Commencement Date” shall mean the date of this Lease. The “Rent Commencement Date” shall be August 1, 2013. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the “Rent Commencement Date” and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, that Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above in the Basic Lease Provisions and the Extension Term that Tenant may elect pursuant to Section 39 hereof.

 

Except as set forth in the Work Letter, if applicable: (i) Tenant shall accept the Premises in their condition as of the Commencement Date, subject to all applicable Legal Requirements (as defined in Section 7 hereof); (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease.

 

Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.

 

2











 

3.                                      Rent.

 

(a)                                 Base Rent. The first month’s Base Rent shall be due and payable on delivery of an executed copy of this Lease to Landlord. Beginning on the Rent Commencement Date, Tenant shall pay to Landlord in advance, without demand, abatement, deduction or set-off, monthly installments of Base Rent on or before the first day of each calendar month during the Term hereof, in lawful money of the United States of America, at the office of Landlord for payment of Rent set forth above, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments of Base Rent for any fractional calendar month shall be prorated. The obligation of Tenant to pay Base Rent and other sums to Landlord and the obligations of Landlord under this Lease are independent obligations. Tenant shall have no right at any time to abate, reduce, or set-off any Rent (as defined in Section 5) due hereunder except for any abatement as may be expressly provided in this Lease.

 

(b)                                 Additional Rent. In addition to Base Rent, Tenant agrees to pay to Landlord as additional rent (“Additional Rent”): (i) Tenant’s Share of “Operating Expenses” (as defined in Section 5), and (ii) any and all other amounts Tenant assumes or agrees to pay under the provisions of this Lease, including, without limitation, any and all other sums that may become due by reason of any default of Tenant or failure to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after any applicable notice and cure period.

 

4.                                      Base Rent Adjustments. Base Rent shall be increased on each anniversary of the first day of the first full month during the Term of this Lease (each an “Adjustment Date”) by multiplying the Base Rent payable immediately before such Adjustment Date by the Rent Adjustment Percentage and adding the resulting amount to the Base Rent payable immediately before such Adjustment Date. Base Rent, as so adjusted, shall thereafter be due as provided herein. Base Rent adjustments for any fractional calendar month shall be prorated.

 

5.                                      Operating Expense Payments. Landlord shall deliver to Tenant a written estimate of Operating Expenses for each calendar year during the Term (“Annual Estimate”), which may be revised by Landlord from time to time during such calendar year. Beginning on the Rent Commencement Date, Tenant shall pay Landlord on or before the first day of each calendar month during the Term hereof an amount equal to 1/12th of Tenant’s Share of the Annual Estimate. Payments for any fractional calendar month shall be prorated.

 

The term “Operating Expenses” means all costs and expenses of any kind or description whatsoever incurred or accrued each calendar year by Landlord with respect to the Project (including, without duplication, Taxes (as defined in Section 9), reasonable reserves consistent with good business practice for future repairs and replacements, and capital repairs and improvements amortized over the lesser of 7 years and the useful life of such capital items), excluding only:

 

(a)                                 the original construction costs of the Project and renovation prior to the date of this Lease and costs of correcting defects in such original construction or renovation;

 

(b)                                 capital expenditures for expansion of the Project;

 

(c)                                  interest, principal payments of Mortgage (as defined in Section 27) debts of Landlord, financing costs and amortization of funds borrowed by Landlord, whether secured or unsecured and all payments of base rent (but not taxes or operating expenses) under any ground lease or other underlying lease of all or any portion of the Project;

 

(d)                                 depreciation of the Project (except for capital improvements, the cost of which are includable in Operating Expenses);

 

3











 

(e)                                  advertising, legal and space planning expenses and leasing commissions and other costs and expenses incurred in procuring and leasing space to tenants for the Project, including any leasing office maintained in the Project, free rent and construction allowances for tenants;

 

(f)                                   legal and other expenses incurred in the negotiation or enforcement of leases;

 

(g)                                  completing, fixturing, improving, renovating, painting, redecorating or other work, which Landlord pays for or performs for other tenants within their premises, and costs of correcting defects in such work;

 

(h)                                 costs of utilities outside normal business hours sold to tenants of the Project;

 

(i)                                     costs to be reimbursed by other tenants of the Project or Taxes to be paid directly by Tenant or other tenants of the Project, whether or not actually paid;

 

(j)                                    salaries, wages, benefits and other compensation paid to officers and employees of Landlord who are not assigned in whole or in part to the operation, management, maintenance or repair of the Project;

 

(k)                                 general organizational, administrative and overhead costs relating to maintaining Landlord’s existence, either as a corporation, partnership, or other entity, including general corporate, legal and accounting expenses;

 

(I)                                   costs (including attorneys’ fees and costs of settlement, judgments and payments in lieu thereof) incurred in connection with disputes with tenants, other occupants, or prospective tenants, and costs and expenses, including legal fees, incurred in connection with negotiations or disputes with employees, consultants, management agents, leasing agents, purchasers or mortgagees of the Building;

 

(m)                             costs incurred by Landlord due to the violation by Landlord, its employees, agents or contractors or any tenant of the terms and conditions of any lease of space in the Project or any Legal Requirement (as defined in Section 7);

 

(n)                                 penalties, fines or interest incurred as a result of Landlord’s inability or failure to make payment of Taxes and/or to file any tax or informational returns when due, or from Landlord’s failure to make any payment of Taxes required to be made by Landlord hereunder before delinquency;

 

(o)                                 overhead and profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for goods and/or services in or to the Project to the extent the same exceeds the costs of such goods and/or services rendered by unaffiliated third parties on a competitive basis;

 

(p)                                 costs of Landlord’s charitable or political contributions, or of fine art maintained at the Project;

 

(q)                                 costs in connection with services (including electricity), items or other benefits of a type which are not standard for the Project and which are not available to Tenant without specific charges therefor, but which are provided to another tenant or occupant of the Project, whether or not such other tenant or occupant is specifically charged therefor by Landlord;

 

(r)                                    costs incurred in the sale or refinancing of the Project;

 

(s)                                   net income taxes of Landlord or the owner of any interest in the Project (except to theextent such net income taxes are in substitution for any Taxes payable hereunder), franchise, capital

 

4











 

stock, gift, estate or inheritance taxes or any federal, state or local documentary taxes imposed against the Project or any portion thereof or interest therein; and

 

(t)                                    any expenses otherwise includable within Operating Expenses to the extent actually reimbursed by persons other than tenants of the Project under leases for space in the Project.

 

Within 90 days after the end of each calendar year (or such longer period as may be reasonably required), Landlord shall furnish to Tenant a statement (an “Annual Statement”) showing in reasonable detail: (a) the total and Tenant’s Share of actual Operating Expenses for the previous calendar year, and (b) the total of Tenant’s payments in respect of Operating Expenses for such year. If Tenant’s Share of actual Operating Expenses for such year exceeds Tenant’s payments of Operating Expenses for such year, the excess shall be due and payable by Tenant as Rent within 30 days after delivery of such Annual Statement to Tenant. If Tenant’s payments of Operating Expenses for such year exceed Tenant’s Share of actual Operating Expenses for such year Landlord shall pay the excess to Tenant within 30 days after delivery of such Annual Statement, except that after the expiration, or earlier termination of the Term or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord.

 

The Annual Statement shall be final and binding upon Tenant unless Tenant, within 30 days after Tenant’s receipt thereof, shall contest any item therein by giving written notice to Landlord, specifying each item contested and the reason therefor. Operating Expenses for the calendar years in which Tenant’s obligation to share therein begins and ends shall be prorated. Notwithstanding anything set forth herein to the contrary, if the Project is not at least 95% occupied on average during any year of the Term, Tenant’s Share of Operating Expenses for such year shall be computed as though the Project had been 95% occupied on average during such year.

 

Tenant’s Share” shall be the percentage set forth in the Basic Lease Provisions as Tenant’s Share as reasonably adjusted by Landlord for changes in the physical size of the Premises or the Project occurring thereafter . Landlord may equitably increase Tenant’s Share for any item of expense or cost reimbursable by Tenant that relates to a repair, replacement, or service that benefits only the Premises or only a portion of the Project that includes the Premises or that varies with occupancy or use. Base Rent, Tenant’s Share of Operating Expenses and all other amounts payable by Tenant to Landlord hereunder are collectively referred to herein as “Rent.”

 

6.                                      Intentionally Deleted.

 

7.                                      Use. The Premises shall be used solely for the Permitted Use set forth in the Basic Lease Provisions, and in compliance with all laws, orders, judgments, ordinances, regulations, codes, directives, permits, licenses, covenants and restrictions now or hereafter applicable to the Premises, and to the use and occupancy thereof, including, without limitation, the Americans With Disabilities Act, 42 U.S.C. § 12101, et seq. (together with the regulations promulgated pursuant thereto, “ADA”) (collectively, “Legal Requirements” and each, a “Legal Requirement”). Tenant shall, upon 5 days’ written notice from Landlord, discontinue any use of the Premises which is declared by any Governmental Authority (as defined in Section 9) having jurisdiction to be a violation of a Legal Requirement. Tenant will not use or permit the Premises to be used for any purpose or in any manner that would void Tenant’s or Landlord’s insurance, increase the insurance risk, or cause the disallowance of any sprinkler or other credits. Tenant shall not permit any part of the Premises to be used as a “place of public accommodation”, as defined in the ADA or any similar legal requirement. Tenant shall reimburse Landlord promptly upon demand for any additional premium charged for any such insurance policy by reason of Tenant’s failure to comply with the provisions of this Section or otherwise caused by Tenant’s use and/or occupancy of the Premises. Tenant will use the Premises in a careful, safe and proper manner and will not commit or permit waste, overload the floor or structure of the Premises, subject the Premises to use that would damage the Premises or obstruct or interfere with the rights of Landlord or other tenants or occupants of the Project, including conducting or giving notice of any auction, liquidation, or going out of business sale

 

5











 

on the Premises, or using or allowing the Premises to be used for any unlawful purpose. Tenant shall cause any equipment or machinery to be installed in the Premises so as to reasonably prevent sounds or vibrations from the Premises from extending into Common Areas, or other space in the Project. Tenant shall not place any machinery or equipment weighing 500 pounds or more in or upon the Premises or transport or move such items through the Common Areas of the Project or in the Project elevators without the prior written consent of Landlord. Except as may be provided under the Work Letter, Tenant shall not, without the prior written consent of Landlord, use the Premises in any manner which will require ventilation, air exchange, heating, gas, steam, electricity or water beyond the existing capacity of the Project as proportionately allocated to the Premises based upon Tenant’s Share as usually furnished for the Permitted Use.

 

(a)                                 Modifications to Common Areas. Landlord shall, as an Operating Expense (to the extent such Legal Requirement is generally applicable to similar buildings in the area in which the Project is located) or at Tenant’s expense (to the extent such Legal Requirement is applicable solely by reason of Tenant’s, as compared to other tenants of the Project, particular use of the Premises) make any alterations or modifications to the Common Areas or the exterior of the Building that are required by Legal Requirements, including the ADA. Tenant, at its sole expense, shall make any alterations or modifications to the interior of the Premises that are required by Legal Requirements (including, without limitation, compliance of the Premises with the ADA). Notwithstanding any other provision herein to the contrary, Tenant shall be responsible for any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action, damages or judgments, and all reasonable expenses incurred in investigating or resisting the same (including, without limitation, reasonable attorneys’ fees, charges and disbursements and costs of suit) (collectively, “Claims”) arising out of or in connection with Legal Requirements, and Tenant shall indemnify, defend, hold and save Landlord harmless from and against any and all Claims arising out of or in connection with any failure of the Premises to comply with any Legal Requirement.

 

8.                                      Holding Over. If, with Landlord’s express written consent, Tenant retains possession of the Premises after the termination of the Term, (i) unless otherwise agreed in such written consent, such possession shall be subject to immediate termination by Landlord at any time, (ii) all of the other terms and provisions of this Lease (including, without limitation, the adjustment of Base Rent pursuant to Section 4 hereof) shall remain in full force and effect (excluding any expansion or renewal option or other similar right or option) during such holdover period, (iii) Tenant shall continue to pay Base Rent in the amount payable upon the date of the expiration or earlier termination of this Lease or such other amount as Landlord may indicate, in Landlord’s sole and absolute discretion, in such written consent, and (iv) all other payments shall continue under the terms of this Lease. If Tenant remains in possession of the Premises after the expiration or earlier termination of the Term without the express written consent of Landlord, (A) Tenant shall become a tenant at sufferance upon the terms of this Lease except that the monthly rental shall be equal to 150% of Rent in effect during the last 30 days of the Term, and (B) Tenant shall be responsible for all damages suffered by Landlord resulting from or occasioned by Tenant’s holding over, including consequential damages. No holding over by Tenant, whether with or without consent of Landlord, shall operate to extend this Lease except as otherwise expressly provided, and this Section 8 shall not be construed as consent for Tenant to retain possession of the Premises. Acceptance by Landlord of Rent after the expiration of the Term or earlier termination of this Lease shall not result in a renewal or reinstatement of this Lease.

 

9.                                      Taxes. Landlord shall pay, as part of Operating Expenses, all taxes, levies, fees, assessments and governmental charges of any kind, existing as of the Commencement Date or thereafter enacted (collectively referred to as “Taxes”), imposed by any federal, state, regional, municipal, local or other governmental authority or agency, including, without limitation, quasi-public agencies (collectively, “Governmental Authority”) during the Term, including, without limitation, all Taxes: (i) imposed on or measured by or based, in whole or in part, on rent payable to (or gross receipts received by) Landlord under this Lease and/or from the rental by Landlord of the Project or any portion thereof, or (ii) based on the square footage, assessed value or other measure or evaluation of any kind of

 

6











 

the Premises or the Project, or (iii) assessed or imposed by or on the operation or maintenance of any portion of the Premises or the Project, including parking, or (iv) assessed or imposed by, or at the direction of, or resulting from Legal Requirements, or interpretations thereof, promulgated by any Governmental Authority, or (v) imposed as a license or other fee, charge, tax, or assessment on Landlord’s business or occupation of leasing space in the Project. Landlord may contest by appropriate legal proceedings the amount, validity, or application of any Taxes or liens securing Taxes. Taxes shall not include any net income taxes imposed on Landlord except to the extent such net income taxes are in substitution for any Taxes payable hereunder. If any such Tax is levied or assessed directly against Tenant, then Tenant shall be responsible for and shall pay the same at such times and in such manner as the taxing authority shall require. Tenant shall pay, prior to delinquency, any and all Taxes levied or assessed against any personal property or trade fixtures placed by Tenant in the Premises, whether levied or assessed against Landlord or Tenant. If any Taxes on Tenant’s personal property or trade fixtures are levied against Landlord or Landlord’s property, or if the assessed valuation of the Project is increased by a value attributable to improvements in or alterations to the Premises, whether owned by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, higher than the base valuation on which Landlord from time-to-time allocates Taxes to all tenants in the Project, Landlord shall have the right, but not the obligation, to pay such Taxes. Landlord’s determination of any excess assessed valuation shall be binding and conclusive, absent manifest error. The amount of any such payment by Landlord shall constitute Additional Rent due from Tenant to Landlord immediately upon demand.

 

10.                               Parking. Subject to all Legal Requirements, Force Majeure, a Taking (as defined in Section 19 below) and the exercise by Landlord of its rights hereunder, Tenant shall have the right, in common with other tenants of the Project pro rata in accordance with the rentable area of the Premises and the rentable areas of the Project occupied by such other tenants, to park in those areas designated for non-reserved parking, subject in each case to Landlord’s rules and regulations. Landlord may allocate parking spaces among Tenant and other tenants in the Project pro rata as described above if Landlord determines that such parking facilities are becoming crowded. Landlord shall not be responsible for enforcing Tenant’s parking rights against any third parties, including other tenants of the Project.

 

11.                               Utilities, Services. The hours of operation of the Project are 24 hours per day, 7 days per week. During such periods, Landlord shall provide, subject to the terms of this Section 11, janitorial services to the Common Areas, water, electricity, heat, light, power, telephone, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), and refuse and trash collection (collectively, “Utilities”). Landlord shall pay, as Operating Expenses or subject to Tenant’s reimbursement obligation below, for all Utilities used on the Premises, all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. Landlord may cause, at Tenant’s expense, any Utilities to be separately metered or charged directly to Tenant by the provider; provided, however, that as part of the Tenant Improvements described in the Work Letter, Tenant shall install a separate electrical meter to measure its consumption of electricity within the Premises. Tenant shall pay directly to the Utility provider, prior to delinquency, any separately metered Utilities and services which may be furnished to Tenant or the Premises during the Term. Tenant shall pay, as part of Operating Expenses, its share of all charges for jointly metered Utilities based upon consumption, as reasonably determined by Landlord. No interruption or failure of Utilities, from any cause whatsoever other than Landlord’s willful misconduct, shall result in eviction or constructive eviction of Tenant, termination of this Lease or the abatement of Rent. Tenant agrees to limit use of water and sewer to normal restroom use.

 

12.                               Alterations and Tenant’s Property. Any alterations, additions, or improvements made to the Premises by or on behalf of Tenant, including additional locks or bolts of any kind or nature upon any doors or windows in the Premises, but excluding installation, removal or realignment of furniture systems (other than removal of furniture systems owned or paid for by Landlord) not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to Building Systems

 

7











 

(as defined in Section 13) (“Alterations”) shall be subject to Landlord’s prior written consent, which may be given or withheld in Landlord’s sole discretion if any such Alteration affects the structure or Building Systems, but which shall otherwise not be unreasonably withheld or delayed. If Landlord approves any Alterations, Landlord may impose such conditions on Tenant in connection with the commencement, performance and completion of such Alterations as Landlord may deem appropriate in Landlord’s reasonable discretion. Any request for approval shall be in writing, delivered not less than 15 business days in advance of any proposed construction, and accompanied by plans, specifications, bid proposals, work contracts and such other information concerning the nature and cost of the alterations as may be reasonably requested by Landlord, including the identities and mailing addresses of all persons performing work or supplying materials. Landlord’s right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to ensure that such plans and specifications or construction comply with applicable Legal Requirements. , Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Legal Requirements and shall implement at its sole cost and expense any alteration or modification required by Legal Requirements as a result of any Alterations. Before Tenant begins any Alteration, Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable law. Tenant shall reimburse Landlord for, and indemnify and hold Landlord harmless from, any expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, delays caused by such work, or inadequate cleanup.

 

Tenant shall furnish security or make other arrangements satisfactory to Landlord to assure payment for the completion of all Alterations work free and clear of liens, and shall provide (and cause each contractor or subcontractor to provide) certificates of insurance (in form and substance satisfactory to Landlord; form ACORD 28 [2006/07] is not satisfactory to Landlord) for workers’ compensation and other coverage in amounts and from an insurance company satisfactory to Landlord protecting Landlord against liability for personal injury or property damage during construction. Upon completion of any Alterations, Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and subcontractors who did the work and final lien waivers from all such contractors and subcontractors; and (ii) “as built” plans for any such Alteration. 

 

Other than (i) the items, if any, listed on Exhibit F attached hereto, (ii) any items agreed by Landlord in writing to be included on Exhibit F in the future, and (iii) any trade fixtures, machinery, equipment and other personal property not paid for out of the TI Fund (as defined in the Work Letter) which may be removed without material damage to the Premises, which damage shall be repaired (including capping or terminating utility hook-ups behind walls) by Tenant during the Term (collectively, “Tenant’s Property”), all property of any kind paid for with the TI Fund, all Alterations, real property fixtures, built-in machinery and equipment, built-in casework and cabinets and other similar additions and improvements built into the Premises so as to become an integral part of the Premises (collectively, “Installations”) shall be and shall remain the property of Landlord during the Term and following the expiration or earlier termination of the Term, shall not be removed by Tenant at any time during the Term and shall remain upon and be surrendered with the Premises as a part thereof in accordance with Section 28 following the expiration or earlier termination of this Lease; provided, however, that Landlord shall, at the time its approval of such Installation is requested, notify Tenant if it has elected to cause Tenant to remove such Installation upon the expiration or earlier termination of this Lease. If Landlord so elects, Tenant shall remove such Installation upon the expiration or earlier termination of this Lease and restore any damage caused by or occasioned as a result of such removal, including, when removing any of Tenant’s Property which was plumbed, wired or otherwise connected to any of the Building Systems, capping off all such connections behind the walls of the Premises and repairing any holes. During any such restoration period, Tenant shall pay Rent to Landlord as provided herein as if said space were otherwise occupied by Tenant.

 

13.                               Landlord’s Repairs. Landlord, as an Operating Expense, shall maintain all of the roof, facade, lobby, common restrooms, common electrical room, and exterior, parking and other Common Areas of the Project, including plumbing, fire sprinklers, elevators and all other building systems serving

 

8











 

the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (I) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall have a reasonable opportunity to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by. Section 18.

 

14.                               Tenant’s Repairs. Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the interior of the Premises, including, without limitation, HVAC serving the Premises, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Such repair and replacement may include capital expenditures and repairs whose benefit may extend beyond the Term. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises.

 

(a)                                 HVAC Unit. Tenant, at its expense, shall at all times during the Term maintain with qualified contractors maintenance and repair contracts (“Maintenance Contracts”) for the rooftop mounted HVAC unit exclusively serving the Premises. The Maintenance Contracts shall be in form and content reasonably satisfactory to Landlord. Landlord shall be a third party beneficiary of the Maintenance Contracts and, within 30 days after Landlord’s request, Tenant shall deliver a copy of the Maintenance Contracts to Landlord.

 

15.                               Mechanic’s Liens. Tenant shall discharge, by bond or otherwise, any mechanic’s lien filed against the Premises or against the Project for work claimed to have been done for, or materials claimed to have been furnished to, Tenant within 10 days after the filing thereof, at Tenant’s sole cost and shall otherwise keep the Premises and the Project free from any liens arising out of work performed, materials furnished or obligations incurred by Tenant. Should Tenant fail to discharge any lien described herein, Landlord shall have the right, but not the obligation, to pay such claim or post a bond or otherwise provide security to eliminate the lien as a claim against title to the Project and the cost thereof shall be immediately due from Tenant as Additional Rent. If Tenant shall lease or finance the acquisition of office equipment, furnishings, or other personal property of a removable nature utilized by Tenant in the operation of Tenant’s business, Tenant warrants that any Uniform Commercial Code Financing Statement filed as a matter of public record by any lessor or creditor of Tenant will upon its face or by exhibit thereto indicate that such Financing Statement is applicable only to removable personal property of Tenant

 

9











 

located within the Premises. In no event shall the address of the Project be furnished on the statement without qualifying language as to applicability of the lien only to removable personal property, located in an identified suite held by Tenant.

 

16.                               Indemnification. Tenant hereby indemnifies and agrees to defend, save and hold Landlord harmless from and against any and all Claims for injury or death to persons or damage to property occurring within or about the Premises, arising directly or indirectly out of use or occupancy of the Premises or a breach or default by Tenant in the performance of any of its obligations hereunder, unless caused solely by the willful misconduct or gross negligence of Landlord. Landlord shall not be liable to Tenant for, and Tenant assumes all risk of damage to, personal property (including, without limitation, loss of records kept within the Premises). Tenant further waives any and all Claims for injury to Tenant’s business or loss of income relating to any such damage or destruction of personal property (including, without limitation, any loss of records). Landlord shall not be liable for any damages arising from any act, omission or neglect of any tenant in the Project or of any other third party.

 

17.                               Insurance. Landlord shall maintain all risk property and, if applicable, sprinkler damage insurance covering the full replacement cost of the Project or such lesser coverage amount as Landlord may elect provided such coverage amount is not less than 90% of such full replacement cost. Landlord shall further procure and maintain commercial general liability insurance with a single loss limit of not less than $2,000,000 for bodily injury and property damage with respect to the Project. Landlord may, but is not obligated to, maintain such other insurance and additional coverages as it may deem necessary, including, but not limited to, flood, environmental hazard and earthquake, loss or failure of building equipment, errors and omissions, rental loss during the period of repair or rebuilding, workers’ compensation insurance and fidelity bonds for employees employed to perform services and insurance for any improvements installed by Tenant or which are in addition to the standard improvements customarily furnished by Landlord without regard to whether or not such are made a part of the Project. All such insurance shall be included as part of the Operating Expenses. The Project may be included in a blanket policy (in which case the cost of such insurance allocable to the Project will be determined by Landlord based upon the insurer’s cost calculations).

 

Tenant, at its sole cost and expense, shall maintain during the Term: all risk property insurance with business interruption and extra expense coverage, covering the full replacement cost of all property and improvements installed or placed in the Premises by Tenant at Tenant’s expense; workers’ compensation insurance with no less than the minimum limits required by law; employer’s liability insurance with such limits as required by law; and commercial general liability insurance, with a minimum limit of not less than $2,000,000 per occurrence for bodily injury and property damage with respect to the Premises. The commercial general liability insurance policy shall name Landlord and Alexandria Real Estate Equities, Inc., and its and their respective members, officers, directors, employees, managers, and agents (collectively, “Landlord Parties”), as additional insureds; insure on an occurrence and not a claims-made basis; be issued by insurance companies which have a rating of not less than policyholder rating of A and financial category rating of at least Class X in “Best’s Insurance Guide”; shall not be cancelable for nonpayment of premium unless 30 days prior written notice shall have been given to Landlord from the insurer; contain a hostile fire endorsement and a contractual liability endorsement; and provide primary coverage to Landlord (any policy issued to Landlord providing duplicate or similar coverage shall be deemed excess over Tenant’s policies). Copies of such policies (if requested by Landlord), or certificates of insurance (in form and substance satisfactory to Landlord; form ACORD 28 [2006/07] is not satisfactory to Landlord) showing the limits of coverage required hereunder and showing Landlord as an additional insured, along with reasonable evidence of the payment of premiums for the applicable period, shall be delivered to Landlord by Tenant upon commencement of the Term and upon each renewal of said insurance. Tenant’s policy may be a “blanket policy” with an aggregate per location endorsement which specifically provides that the amount of insurance shall not be prejudiced by other losses covered by the policy. Tenant shall, at least 5 days prior to the expiration of such policies, furnish Landlord with renewal certificates.

 

10









 

In each instance where insurance is to name Landlord as an additional insured, Tenant shall upon written request of Landlord also designate and furnish certificates so evidencing Landlord as additional insured to: (i) any lender of Landlord holding a security interest in the Project or any portion thereof, (ii) the landlord under any lease wherein Landlord is tenant of the real property on which the Project is located, if the interest of Landlord is or shall become that of a tenant under a ground or other underlying lease rather than that of a fee owner, and/or (iii) any management company retained by Landlord to manage the Project.

 

The property insurance obtained by Landlord and Tenant shall include a waiver of subrogation by the insurers and all rights based upon an assignment from its insured, against Landlord or Tenant, and their respective officers, directors, employees, managers, agents, invitees and contractors (“Related Parties”), in connection with any loss or damage thereby insured against. Neither party nor its respective Related Parties shall be liable to the other for loss or damage caused by any risk insured against under property insurance required to be maintained hereunder, and each party waives any claims against the other party, and its respective Related Parties, for such loss or damage. The failure of a party to insure its property shall not void this waiver. Landlord and its respective Related Parties shall not be liable for, and Tenant hereby waives all claims against such parties for, business interruption and losses occasioned thereby sustained by Tenant or any person claiming through Tenant resulting from any accident or occurrence in or upon the Premises or the Project from any cause whatsoever. If the foregoing waivers shall contravene any law with respect to exculpatory agreements, the liability of Landlord or Tenant shall be deemed not released but shall be secondary to the other’s insurer.

 

Landlord may require insurance policy limits to be raised to conform with requirements of Landlord’s lender and/or to bring coverage limits to levels then being generally required of new tenants within the Project.

 

18.          Restoration. If, at any time during the Term, the Project or the Premises are damaged or destroyed by a fire or other insured casualty, Landlord shall notify Tenant within 60 days after discovery of such damage as to the amount of time Landlord reasonably estimates it will take to restore the Project or the Premises, as applicable (“Restoration Period”). If the Restoration Period is estimated to exceed 12 months (“Maximum Restoration Period”), Landlord may, in such notice, elect to terminate this Lease as of the date that is 75 days after the date of discovery of such damage or destruction; provided, however, that notwithstanding Landlord’s election to restore, Tenant may elect to terminate this Lease by written notice to Landlord delivered within 5 business days of receipt of a notice from Landlord estimating a Restoration Period for the Premises longer than the Maximum Restoration Period. Unless either Landlord or Tenant so elects to terminate this Lease, Landlord shall, subject to receipt of sufficient insurance proceeds (with any deductible to be treated as a current Operating Expense), promptly restore the Premises (excluding the improvements installed by Tenant or by Landlord and paid for by Tenant), subject to delays arising from the collection of insurance proceeds, from Force Majeure events or as needed to obtain any license, clearance or other authorization of any kind required to enter into and restore the Premises issued by any Governmental Authority having jurisdiction over the use, storage, handling, treatment, generation, release, disposal, removal or remediation of Hazardous Materials (as defined in Section 30) in, on or about the Premises (collectively referred to herein as “Hazardous Materials Clearances”); provided, however, that if repair or restoration of the Premises is not substantially complete as of the end of the Maximum Restoration Period or, if longer, the Restoration Period, Landlord may, in its sole and absolute discretion, elect not to proceed with such repair and restoration, in which event Landlord shall be relieved of its obligation to make such repairs or restoration and this Lease shall terminate as of the date that is 75 days after the later of: (i) discovery of such damage or destruction, or (ii) the date all required Hazardous Materials Clearances are obtained, but Landlord shall retain any Rent paid and the right to any Rent payable by Tenant prior to such election by Landlord or Tenant.

 

Tenant, at its expense, shall promptly perform, subject to delays arising from the collection of insurance proceeds, from Force Majeure (as defined in Section 34) events or to obtain Hazardous

 

11











 

Material Clearances, all repairs or restoration not required to be done by Landlord and shall promptly re-enter the Premises and commence doing business in accordance with this Lease. Notwithstanding the foregoing, Landlord may terminate this Lease if the Premises are damaged during the last year of the Term and Landlord reasonably estimates that it will take more than 2 months to repair such damage, or if insurance proceeds are not available for such restoration. Rent shall be abated from the date all required Hazardous Material Clearances are obtained until the Premises are repaired and restored, in the proportion which the area of the Premises, if any, which is not usable by Tenant bears to the total area of the Premises, unless Landlord provides Tenant with other space during the period of repair that is suitable for the temporary conduct of Tenant’s business. Such abatement shall be the sole remedy of Tenant, and except as provided in this Section 18, Tenant waives any right to terminate this Lease by reason of damage or casualty loss.

 

The provisions of this Lease, including this Section 18, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, or any other portion of the Project, and any statute or regulation which is now or may hereafter be in effect shall have no application to this Lease or any damage or destruction to all or any part of the Premises or any other portion of the Project, the parties hereto expressly agreeing that this Section 18 sets forth their entire understanding and agreement with respect to such matters.

 

19.          Condemnation. If the whole or any material part of the Premises or the Project is taken for any public or quasi-public use under governmental law, ordinance, or regulation, or by right of eminent domain, or by private purchase in lieu thereof (a “Taking” or “Taken”), and the Taking would in Landlord’s reasonable judgment either prevent or materially interfere with Tenant’s use of the Premises or materially interfere with or impair Landlord’s ownership or operation of the Project, then upon written notice by Landlord this Lease shall terminate and Rent shall be apportioned as of said date. If part of the Premises shall be Taken, and this Lease is not terminated as provided above, Landlord shall promptly restore the Premises and the Project as nearly as is commercially reasonable under the circumstances to their condition prior to such partial Taking and the rentable square footage of the Building, the rentable square footage of the Premises, Tenant’s Share of Operating Expenses and the Rent payable hereunder during the unexpired Term shall be reduced to such extent as may be fair and reasonable under the circumstances. Upon any such Taking, Landlord shall be entitled to receive the entire price or award from any such Taking without any payment to Tenant, and Tenant hereby assigns to Landlord Tenant’s interest, if any, in such award. Tenant shall have the right, to the extent that same shall not diminish Landlord’s award, to make a separate claim against the condemning authority (but not Landlord) for such compensation as may be separately awarded or recoverable by Tenant for moving expenses and damage to Tenant’s trade fixtures, if a separate award for such items is made to Tenant. Tenant hereby waives any and all rights it might otherwise have pursuant to any provision of state law to terminate this Lease upon a partial Taking of the Premises or the Project.

 

20.           Events of Default. Each of the following events shall be a default (“Default”) by Tenant under this Lease:

 

(a)            Payment Defaults. Tenant shall fail to pay any installment of Rent or any other payment hereunder when due.

 

(b)           Insurance. Any insurance required to be maintained by Tenant pursuant to this Lease shall be canceled or terminated or shall expire or shall be reduced or materially changed, or Landlord shall receive a notice of nonrenewal of any such insurance and Tenant shall fail to obtain replacement insurance at least 20 days before the expiration of the current coverage.

 

(c)           Abandonment. Tenant shall abandon the Premises.

 

12











 

(d)           Improper Transfer. Tenant shall assign, sublease or otherwise transfer or attempt to transfer all or any portion of Tenant’s interest in this Lease or the Premises except as expressly permitted herein, or Tenant’s interest in this Lease shall be attached, executed upon, or otherwise judicially seized and such action is not released within 90 days of the action.

 

(e)           Liens. Tenant shall fail to discharge or otherwise obtain the release of any lien placed upon the Premises in violation of this Lease within 10 days after any such lien is filed against the Premises.

 

(f)            Insolvency Events. Tenant or any guarantor or surety of Tenant’s obligations hereunder shall: (A) make a general assignment for the benefit of creditors; (B) commence any case, proceeding or other action seeking to have an order for relief entered on its behalf as a debtor or to adjudicate it a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of it or its debts or seeking appointment of a receiver, trustee, custodian or other similar official for it or for all or of any substantial part of its property (collectively a “Proceeding for Relief”); (C) become the subject of any Proceeding for Relief which is not dismissed within 90 days of its filing or entry; or (D) die or suffer a legal disability (if Tenant, guarantor, or surety is an individual) or be dissolved or otherwise fail to maintain its legal existence (if Tenant, guarantor or surety is a corporation, partnership or other entity).

 

(g)           Estoppel Certificate or Subordination Agreement. Tenant fails to execute any document required from Tenant under Sections 23 or 27 within 5 days after a second notice requesting such document.

 

(h)           Default under Related Lease. Tenant defaults beyond the expiration of any applicable notice and cure period under the Standard Form Multi-Tenant Net Lease (Non-California) dated April 19, 1999, as amended, between Tenant (as successor in interest to Shire Laboratories Inc.) and ARE Acquisitions, LLC for premises located at 1550 East Gude Drive, Rockville, Maryland 20850.

 

(i)            Other Defaults. Tenant shall fail to comply with any provision of this Lease other than those specifically referred to in this Section 20, and, except as otherwise expressly provided herein, such failure shall continue for a period of 10 days after written notice thereof from Landlord to Tenant.

 

Any notice given under Section 20(i) hereof shall: (i) specify the alleged default, (ii) demand that Tenant cure such default, (iii) be in lieu of, and not in addition to, or shall be deemed to be, any notice required under any provision of applicable law, and (iv) not be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice; provided that if the nature of Tenant’s default pursuant to Section 20(i) is such that it cannot be cured by the payment of money and reasonably requires more than 10 days to cure, then Tenant shall not be deemed to be in default if Tenant commences such cure within said 10 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no later than 30 days from the date of Landlord’s notice.

 

21.          Landlord’s Remedies.

 

(a)           Interest. Upon a Default by Tenant hereunder, Landlord may, without waiving or releasing any obligation of Tenant hereunder, make such payment or perform such act. All sums so paid or incurred by Landlord, together with interest thereon, from the date such sums were paid or incurred, at the annual rate equal to 12% per annum or the highest rate permitted by law (“Default Rate”), whichever is less, shall be payable to Landlord on demand as Additional Rent. Except as expressly set forth in clause (d) below, nothing herein shall be construed to create or impose a duty on Landlord to mitigate any damages resulting from Tenant’s Default hereunder.

 

13











 

(b)           Late Payment Rent. Late payment by Tenant to Landlord of Rent and other sums due will cause Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult and impracticable to ascertain. Such costs include, but are not limited to, processing and accounting charges and late charges which may be imposed on Landlord under any Mortgage covering the Premises. Therefore, if any installment of Rent due from Tenant is not received by Landlord within 10 days after the date such payment is due, Tenant shall pay to Landlord an additional sum of 6% of the overdue Rent as a late charge (provided that Tenant shall not be required to pay such late charge upon the first occurrence of a late payment by Tenant of Rent). The parties agree that this late charge represents a fair and reasonable estimate of the costs Landlord will incur by reason of late payment by Tenant. In addition to the late charge, Rent not paid when due shall bear interest at the Default Rate from the 5th day after the date due until paid.

 

(c)           Re-Entry. Landlord shall have the right, immediately or at any time thereafter, without further notice to Tenant (unless otherwise provided herein), to enter the Premises, without terminating this Lease or being guilty of trespass, and do any and all acts as Landlord may deem necessary, proper or convenient to cure such default, for the account and at the expense of Tenant, any notice to quit or notice of Landlord’s intention to re-enter being hereby expressly waived, and Tenant agrees to pay to Landlord as Additional Rent all damage and/or expense incurred by Landlord in so doing, including interest at the Default Rate, from the due date until the date payment is received by Landlord.

 

(d)           Termination. Upon a Default by Tenant hereunder, Landlord shall have the right to terminate this Lease and Tenant’s right to possession of the Premises and, with or without legal process, take possession of the Premises and remove Tenant, any occupant and any property therefrom, using such force as may be necessary, without being guilty of trespass and without relinquishing any rights of Landlord against Tenant, any notice to quit, or notice of Landlord’s intention to re-enter being hereby expressly waived. Landlord shall be entitled to recover damages from Tenant for all amounts covenanted to be paid during the remainder of the Term (except for the period of any holdover by Tenant, in which case the monthly rental rate stated at Section 8 herein shall apply), which may be accelerated by Landlord at its option, together with (i) all expenses of any proceedings (including, but not limited to, the expenses set forth in Section 22(f) below) which may be necessary in order for Landlord to recover possession of the Premises, (ii) the expenses of the re-renting of the Premises (including, but not limited to, any commissions paid to any real estate agent, advertising expense and the costs of such alterations, repairs, replacements or modifications that Landlord, in its sole judgment, considers advisable and necessary for the purpose of re-renting), and (iii) interest computed at the Default Rate from the due date until paid; provided, however, that there shall be credited against the amount of such damages all amounts received by Landlord from such re-renting of the Premises, with any overage being refunded to Tenant. Landlord shall in no event be liable in any way whatsoever for failure to re-rent the Premises or, in the event that the Premises are re-rented, for failure to collect the rent thereof under such re-renting and, except as expressly provided in the following paragraph, Tenant expressly waives any duty of the Landlord to mitigate damages. No act or thing done by Landlord shall be deemed to be an acceptance of a surrender of the Premises, unless Landlord shall execute a written agreement of surrender with Tenant. Tenant’s liability hereunder shall not be terminated by the execution of a new lease of the Premises by Landlord, unless that new lease expressly so states. In the event Landlord does not exercise its option to accelerate the payment of amounts owed as provided hereinabove, then Tenant agrees to pay to Landlord, upon demand, the amount of damages herein provided after the amount of such damages for any month shall have been ascertained; provided, however, that any expenses incurred by Landlord shall be deemed to be a part of the damages for the month in which they were incurred. Separate actions may be maintained each month or at other times by Landlord against Tenant to recover the damages then due, without waiting until the end of the term of this Lease to determine the aggregate amount of such damages. Tenant hereby expressly waives any and all rights of redemption granted by or under any present or future laws in the event of Tenant being evicted or being dispossessed for any cause, or in the event of Landlord obtaining possession of the Premises by reason of the violation by Tenant of any of the covenants and conditions of this Lease.

 

14











 

Except as expressly provided in this paragraph and as a material inducement for Landlord to enter into this Lease, Tenant agrees and acknowledges that Landlord shall have no obligation whatsoever to mitigate any damages resulting from a Default by Tenant under this Lease. In case of a Default by Tenant under this Lease, Landlord’s sole obligation to so mitigate its damages shall be to list the Premises with a licensed broker. On compliance with such listing requirement regarding the re-letting of the Premises after a Default by Tenant, Landlord shall be deemed to have fully satisfied Landlord’s obligation to mitigate damages under this Lease regardless of any contrary Legal Requirement in effect on the Commencement Date or at the time of Tenant’s Default. Tenant waives and releases, to the fullest extent permissible under any Legal Requirement, any right to assert in any action by Landlord to enforce the terms of this Lease, any defense, counterclaim, or rights of setoff or recoupment respecting the mitigation of damages by Landlord.

 

(e)           Intentionally Deleted.

 

(f)            Expenses. Tenant shall pay, as Additional Rent and immediately upon written demand from Landlord, all costs and expenses incurred by Landlord, including, but not limited to, attorneys’ fees, expert witness fees, paralegal fees, other litigation expenses (such as expenses for photocopying, electronic legal research, and deposition transcripts), and court costs in connection with or arising out of any Default by Tenant under this Lease, including, but not limited to, any action or proceeding brought by Landlord to enforce any obligation of Tenant under this Lease or the right of Landlord in or to the Premises. Such expenses are recoverable at all levels, including appeals and post judgment actions or proceedings. The giving of a notice of Default by Landlord shall constitute part of an action or proceeding under this Lease, entitling Landlord to reimbursement of such fees and expenses, even if an action or proceeding is not commenced in a court of law and regardless of whether the Default is cured.

 

(g)           Other Remedies. In addition to the foregoing, Landlord, at its option, without furthernotice or demand to Tenant, shall have all other rights and remedies provided at law or in equity.

 

22.          Assignment and Subletting.

 

(a)           General Prohibition. Without Landlord’s prior written consent subject to and on the conditions described in this Section 22, Tenant shall not, directly or indirectly, voluntarily or by operation of law, assign this Lease or sublease the Premises or any part thereof or mortgage, pledge, or hypothecate its leasehold interest or grant any concession or license within the Premises, and any attempt to do any of the foregoing shall be void and of no effect. If Tenant is a corporation, partnership or limited liability company, the shares or other ownership interests thereof which are not actively traded upon a stock exchange or in the over-the-counter market, a transfer or series of transfers whereby 25% or more of the issued and outstanding shares or other ownership interests of such corporation are, or voting control is, transferred (but excepting transfers upon deaths of individual owners) from a person or persons or entity or entities which were owners thereof at time of execution of this Lease to persons or entities who were not owners of shares or other ownership interests of the corporation, partnership or limited liability company at time of execution of this Lease, shall be deemed an assignment of this Lease requiring the consent of Landlord as provided in this Section 22.

 

(b)           Permitted Transfers. If Tenant desires to assign, sublease, hypothecate or otherwise transfer this Lease or sublet the Premises, then at least 15 business days, but not more than 45 business days, before the date Tenant desires the assignment or sublease to be effective (“Assignment Date”), Tenant shall give Landlord a notice (“Assignment Notice”) containing such information about the proposed assignee or sublessee, including the proposed use of the Premises and any Hazardous Materials proposed to be used, stored handled, treated, generated in or released or disposed of from the Premises, the Assignment Date, any relationship between Tenant and the proposed assignee or sublessee, and all material terms and conditions of the proposed assignment or sublease, including a copy of any proposed assignment or sublease in its final form, and such other information as Landlord may deem reasonably necessary or appropriate to its consideration whether to grant its consent.

 

15











 

Landlord may, by giving written notice to Tenant within 15 business days after receipt of the Assignment Notice: (i) grant such consent, (ii) refuse such consent, in its sole and absolute discretion, if the proposed assignment, hypothecation or other transfer or subletting concerns more than (together with all other then effective subleases) 50% of the Premises, (iii) refuse such consent, in its reasonable discretion, if the proposed subletting concerns (together with all other then effective subleases) 50% or less of the Premises (provided that Landlord shall further have the right to review and approve or disapprove the proposed form of sublease prior to the effective date of any such subletting), or (iv) terminate this Lease with respect to the space described in the Assignment Notice as of the Assignment Date (an “Assignment Termination”). If Landlord delivers notice of its election to exercise an Assignment Termination, Tenant shall have the right to withdraw such Assignment Notice by written notice to Landlord of such election within 5 business days after Landlord’s notice electing to exercise the Assignment Termination. If Tenant withdraws such Assignment Notice, this Lease shall continue in full force and effect. If Tenant does not withdraw such Assignment Notice, this Lease, and the term and estate herein granted, shall terminate as of the Assignment Date with respect to the space described in such Assignment Notice. No failure of Landlord to exercise any such option to terminate this Lease, or to deliver a timely notice in response to the Assignment Notice, shall be deemed to be Landlord’s consent to the proposed assignment, sublease or other transfer. Tenant shall pay to Landlord a fee equal to $1,500 in connection with its consideration of any Assignment Notice and/or its preparation or review of any consent documents.

 

(c)           Additional Conditions. As a condition to any such assignment or subletting, whether or not Landlord’s consent is required, Landlord may require:

 

(i)            that any assignee or subtenant agree, in writing at the time of such assignment or subletting, that if Landlord gives such party notice that Tenant is in default under this Lease, such party shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments will be received by Landlord without any liability except to credit such payment against those due under this Lease, and any such third party shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, in no event shall Landlord or its successors or assigns be obligated to accept such attornment; and 

 

(ii)           A list of Hazardous Materials, certified by the proposed assignee or sublessee to be true and correct, which the proposed assignee or sublessee intends to use, store, handle, treat, generate in or release or dispose of from the Premises, together with copies of all documents relating to such use, storage, handling, treatment, generation, release or disposal of Hazardous Materials by the proposed assignee or subtenant in the Premises or on the Project, prior to the proposed assignment or subletting, including, without limitation: permits; approvals; reports and correspondence; storage and management plans; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given its written consent to do so, which consent may be withheld in Landlord’s sole and absolute discretion); and all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks. Neither Tenant nor any such proposed assignee or subtenant is required, however, to provide Landlord with any portion(s) of the such documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities.

 

(d)           No Release of Tenant, Sharing of Excess Rents. Notwithstanding any assignment or subletting, Tenant and any guarantor or surety of Tenant’s obligations under this Lease shall at all times remain fully and primarily responsible and liable for the payment of Rent and for compliance with all of Tenant’s other obligations under this Lease. If the Rent due and payable by a sublessee or assignee (or a combination of the rental payable under such sublease or assignment plus any bonus or other

 

16











 

consideration therefor or incident thereto in any form) exceeds the rental payable under this Lease (excluding however, any Rent payable under this Section) (“Excess Rent”), then Tenant shall be bound and obligated to pay Landlord as Additional Rent hereunder 50% of such Excess Rent within 10 days following receipt thereof by Tenant. If Tenant shall sublet the Premises or any part thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as security for Tenant’s obligations under this Lease, all rent from any such subletting, and Landlord as assignee and as attorney-in-fact for Tenant, or a receiver for Tenant appointed on Landlord’s application, may collect such rent and apply it toward Tenant’s obligations under this Lease; except that, until the occurrence of a Default, Tenant shall have the right to collect such rent.

 

(e)           No Waiver. The consent by Landlord to an assignment or subletting shall not relieve Tenant or any assignees of this Lease or any sublessees of the Premises from obtaining the consent of Landlord to any further assignment or subletting nor shall it release Tenant or any assignee or sublessee of Tenant from full and primary liability under this Lease. The acceptance of Rent hereunder, or the acceptance of performance of any other term, covenant, or condition thereof, from any other person or entity shall not be deemed to be a waiver of any of the provisions of this Lease or a consent to any subletting, assignment or other transfer of the Premises.

 

23.          Estoppel Certificate. Tenant shall, within 10 business days of written notice from Landlord, execute, acknowledge and deliver a statement in writing in any form reasonably requested by a proposed lender or purchaser, (i) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease as so modified is in full force and effect) and the dates to which the rental and other charges are paid in advance, if any, (ii) acknowledging that there are not any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (iii) setting forth such further information with respect to the status of this Lease or the Premises as may be requested thereon. Any such statement may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the real property of which the Premises are a part. Tenant’s failure to deliver such statement within such time shall, at the option of Landlord, be conclusive upon Tenant that this Lease is in full force and effect and without modification except as may be represented by Landlord in any certificate prepared by Landlord and delivered to Tenant for execution.

 

24.          Quiet Enjoyment. So long as Tenant shall perform all of the covenants and agreements herein required to be performed by Tenant, Tenant shall, subject to the terms of this Lease, at all times during the Term, have peaceful and quiet enjoyment of the Premises against any person claiming by, through or under Landlord.

 

25.          Prorations. All prorations required or permitted to be made hereunder shall be made on the basis of a 360 day year and 30 day months.

 

26.          Rules and Regulations. Tenant shall, at all times during the Term and any extension thereof, comply with all reasonable rules and regulations at any time or from time to time established by Landlord covering use of the Premises and the Project. The current rules and regulations are attached hereto as Exhibit E. If there is any conflict between said rules and regulations and other provisions of this Lease, the terms and provisions of this Lease shall control. Landlord shall not have any liability or obligation for the breach of any rules or regulations by other tenants in the Project and shall not enforce such rules and regulations in a discriminatory manner.

 

27.          Subordination. This Lease and Tenant’s interest and rights hereunder are hereby made and shall be subject and subordinate at all times to the lien of any Mortgage now existing or hereafter created on or against the Project or the Premises, and all amendments, restatements, renewals, modifications, consolidations, refinancing, assignments and extensions thereof, without the necessity of any further instrument or act on the part of Tenant; provided, however that so long as there is no Default hereunder, Tenant’s right to possession of the Premises shall not be disturbed by the Holder of any such Mortgage. Tenant agrees, at the election of the Holder of any such Mortgage, to attorn to any such

 

17











 

Holder. Tenant agrees upon demand to execute, acknowledge and deliver such instruments, confirming such subordination, and such instruments of attornment as shall be requested by any such Holder, provided any such instruments contain appropriate non-disturbance provisions assuring Tenant’s quiet enjoyment of the Premises as set forth in Section 24 hereof. Tenant hereby appoints Landlord attorney-in-fact for Tenant irrevocably (such power of attorney being coupled with an interest) to execute, acknowledge and deliver any such instrument and instruments for and in the name of Tenant and to cause any such instrument to be recorded. Notwithstanding the foregoing, any such Holder may at any time subordinate its Mortgage to this Lease, without Tenant’s consent, by notice in writing to Tenant, and thereupon this Lease shall be deemed prior to such Mortgage without regard to their respective dates of execution, delivery or recording and in that event such Holder shall have the same rights with respect to this Lease as though this Lease had been executed prior to the execution, delivery and recording of such Mortgage and had been assigned to such Holder. The term “Mortgage” whenever used in this Lease shall be deemed to include deeds of trust, security assignments and any other encumbrances, and any reference to the “Holder” of a Mortgage shall be deemed to include the beneficiary under a deed of trust.

 

28.          Surrender. Upon the expiration of the Term or earlier termination of Tenant’s right of possession, Tenant shall surrender the Premises to Landlord in the same condition as received, subject to any Alterations or Installations permitted by Landlord to remain in the Premises, free of Hazardous Materials brought upon, kept, used, stored, handled, treated, generated in, or released or disposed of from, the Premises by any person other than a Landlord Party (collectively, “Tenant HazMat Operations”) and released of all Hazardous Materials Clearances, broom clean, ordinary wear and tear and casualty loss and condemnation covered by Sections 18 and 19 excepted.

 

Tenant shall immediately return to Landlord all keys and/or access cards to parking, the Project, restrooms or all or any portion of the Premises furnished to or otherwise procured by Tenant. If any such access card or key is lost, Tenant shall pay to Landlord, at Landlord’s election, either the cost of replacing such lost access card or key or the cost of reprogramming the access security system in which such access card was used or changing the lock or locks opened by such lost key. Any Tenant’s Property, Alterations and property not so removed by Tenant as permitted or required herein shall be deemed abandoned and may be stored, removed, and disposed of by Landlord at Tenant’s expense, and Tenant waives all claims against Landlord for any damages resulting from Landlord’s retention and/or disposition of such property. All obligations of Tenant hereunder not fully performed as of the termination of the Term, including the obligations of Tenant under Section 30 hereof, shall survive the expiration or earlier termination of the Term, including, without limitation, indemnity obligations, payment obligations with respect to Rent and obligations concerning the condition and repair of the Premises.

 

29.          Waiver of Jury Trial. TENANT AND LANDLORD WAIVE ANY RIGHT TO TRIAL BY JURY OR TO HAVE A JURY PARTICIPATE IN RESOLVING ANY DISPUTE, WHETHER SOUNDING IN CONTRACT, TORT, OR OTHERWISE, BETWEEN LANDLORD AND TENANT ARISING OUT OF THIS LEASE OR ANY OTHER INSTRUMENT, DOCUMENT, OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION HEREWITH OR THE TRANSACTIONS RELATED HERETO.

 

30.          Environmental Requirements.

 

(a)           Prohibition/Compliance. Except for Hazardous Material contained in products customarily used by tenants in de minimus quantities for ordinary cleaning and office purposes, Tenant shall not permit or cause any party to bring any Hazardous Material upon the Premises or the Project or use, store, handle, treat, generate, manufacture, transport, release or dispose of any Hazardous Material in, on or from the Premises or the Project without Landlord’s prior written consent which may be withheld in Landlord’s sole discretion. Tenant, at its sole cost and expense, shall operate its business in the Premises in strict compliance with all Environmental Requirements and shall remove or remediate in a manner satisfactory to Landlord any Hazardous Materials released on or from the Project by Tenant or any Tenant Party. Tenant shall complete and certify disclosure statements as requested by Landlord from time to time relating to Tenant’s use, storage, handling, treatment, generation, manufacture,

 

18











 

transportation, release or disposal of Hazardous Materials on or from the Premises. As used herein, (i) the term “Environmental Requirements” means all applicable present and future statutes, regulations, ordinances, rules, codes, judgments, orders or other similar enactments of any Governmental Authority regulating or relating to health, safety, or environmental conditions on, under, or about the Premises or the Project, or the environment, including without limitation, the following: the Comprehensive Environmental Response, Compensation and Liability Act; the Resource Conservation and Recovery Act; and all state and local counterparts thereto, and any regulations or policies promulgated or issued thereunder, and (ii) the term “Hazardous Materials” means and includes any substance, material, waste, pollutant, or contaminant listed or defined as hazardous or toxic, or regulated by reason of its impact or potential impact on humans, animals and/or the environment under any Environmental Requirements, asbestos and petroleum, including crude oil or any fraction thereof, natural gas liquids, liquefied natural gas, or synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas). As defined in Environmental Requirements, Tenant is and shall be deemed to be the “operator” of Tenant’s “facility” and the “owner” of all Hazardous Materials brought on the Premises by Tenant or any Tenant Party, and the wastes, by-products, or residues generated, resulting, or produced therefrom.

 

(b)           Indemnity. Tenant hereby indemnifies and shall defend and hold Landlord, its officers, directors, employees, agents and contractors harmless from any and all actions (including, without limitation, remedial or enforcement actions of any kind, administrative or judicial proceedings, and orders or judgments arising out of or resulting therefrom), costs, claims, damages (including, without limitation, punitive damages and damages based upon diminution in value of the Premises or the Project, or the loss of, or restriction on, use of the Premises or any portion of the Project), expenses (including, without limitation, attorneys’, consultants’ and experts’ fees, court costs and amounts paid in settlement of any claims or actions), fines, forfeitures or other civil, administrative or criminal penalties, injunctive or other relief (whether or not based upon personal injury, property damage, or contamination of, or adverse effects upon, the environment, water tables or natural resources), liabilities or losses (collectively, “Environmental Claims”) which arise during or after the Term as a result of such contamination. Notwithstanding anything to the contrary contained in this Section 30, Tenant shall not be responsible for, and the indemnification and hold harmless obligation set forth in this paragraph shall not apply to, (1) the presence of any Hazardous Materials in the Premises that migrated from outside of the Premises into the Premises unless the presence of such Hazardous Materials (i) is the result of a breach by Tenant of any of its obligations under this Lease, or (ii) was caused, contributed to, or exacerbated by Tenant or any Tenant Party, or (2) any Hazardous Materials that existed in the Premises as of the Commencement Date and were not brought, discharged, or released onto the Premises by Tenant or any Tenant Party. This indemnification of Landlord by Tenant includes, without limitation, costs incurred in connection with any investigation of site conditions or any cleanup, remedial, removal, or restoration work required by any federal, state or local Governmental Authority because of Hazardous Materials present in the air, soil or ground water above, on, or under the Premises. Without limiting the foregoing, if the presence of any Hazardous Materials on the Premises, the Project or any adjacent property caused or permitted by Tenant or any Tenant Party results in any contamination of the Premises, the Project or any adjacent property, Tenant shall promptly take all actions at its sole expense and in accordance with applicable law as are necessary to return the Premises, the Project or any adjacent property to the condition existing prior to the time of such contamination, provided that Landlord’s approval of such action shall first be obtained, which approval shall not unreasonably be withheld so long as such actions would not potentially have any material adverse long-term or short-term effect on the Premises or the Project.

 

(c)           Landlord’s Tests. Landlord shall have access to, and a right to perform inspections and tests of, the Premises to determine Tenant’s compliance with Environmental Requirements, its obligations under this Section 30, or the environmental condition of the Premises or the Project. In connection with such testing, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such non-proprietary information concerning the use of Hazardous Materials in or about the Premises by Tenant or any Tenant Party. Access shall be granted to Landlord upon Landlord’s prior notice to Tenant and at such times so as to minimize, so far as may be reasonable under the circumstances, any disturbance to

 

19











 

Tenant’s operations. Such inspections and tests shall be conducted at Landlord’s expense, unless such inspections or tests reveal that Tenant has not complied with any Environmental Requirement, in which case Tenant shall reimburse Landlord for the reasonable cost of such inspection and tests. Tenant shall, at its sole cost and expense, promptly and satisfactorily remediate any environmental conditions identified by such testing in accordance with all Environmental Requirements. Landlord’s receipt of or satisfaction with any environmental assessment in no way waives any rights that Landlord may have against Tenant.

 

(d)           Control Areas. Tenant shall be allowed to utilize up to its pro rata share of the Hazardous Materials inventory within any control area or zone (located within the Premises), as designated from time to time by the applicable building code or other Legal Requirement, for Hazardous Materials use or storage. As used in the preceding sentence, Tenant’s pro rata share of any control area or zone located within the Premises shall be determined based on the rentable square footage that Tenant leases within the applicable control area or zone. For purposes of example only, if a control area or zone contains 10,000 rentable square feet and 2,000 rentable square feet of a tenant’s premises are located within such control area or zone (while such premises as a whole contains 5,000 rentable square feet), the applicable tenant’s pro rata share of such control area or zone would be 20%.

 

(e)           Tenant’s Obligations. Tenant’s obligations under this Section 30 shall survive the expiration or earlier termination of this Lease for the applicable statute of limitations period under federal, state, or local Legal Requirement. During any period of time after the expiration or earlier termination of this Lease required by Tenant or Landlord to complete the removal from the Premises of any Hazardous Materials (including, without limitation, the release and termination of any licenses or permits restricting the use of the Premises), Tenant shall continue to pay the full Rent in accordance with this Lease for any portion of the Premises not relet by Landlord in Landlord’s sole discretion, which Rent shall be prorated daily.

 

31.          Tenant’s Remedies/Limitation of Liability. Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder.

 

All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.

 

32.          Inspection and Access. Landlord and its agents, representatives, and contractors may enter the Premises at any reasonable time to (a) inspect the Premises, (b) make such repairs as may be required or permitted pursuant to this Lease and for any other business purpose, and (c) gain access to the Main Electrical Room (as depicted on Exhibit A attached hereto) for the purpose of, among other things, reading the electrical meters contained in such room and performing maintenance, repair, and replacement activities. Landlord and Landlord’s representatives may enter the Premises during business hours on not less than 48 hours advance written notice (except in the case of emergencies in which case no such notice shall be required and such entry may be at any time) for the purpose of effecting any such

 

20









 

repairs, inspecting the Premises, showing the Premises to prospective purchasers and, during the last year of the Term, to prospective tenants or for any other business purpose. Landlord may erect a suitable sign on the Premises stating the Premises are available to let or that the Project is available for sale. Landlord may grant easements, make public dedications, designate Common Areas and create restrictions on or about the Premises, provided that no such easement, dedication, designation or restriction materially, adversely affects Tenant’s use or occupancy of the Premises for the Permitted Use. At Landlord’s request, Tenant shall execute such instruments as may be necessary for such easements, dedications or restrictions. Tenant shall at all times, except in the case of emergencies, have the right to escort Landlord or its agents, representatives, contractors or guests while the same are in the Premises, provided such escort does not materially and adversely affect Landlord’s access rights hereunder.

 

33.                               Security. Tenant acknowledges and agrees that security devices and services, if any, while intended to deter crime may not in given instances prevent theft or other criminal acts and that Landlord is not providing any security services with respect to the Premises. Tenant agrees that Landlord shall not be liable to Tenant for, and Tenant waives any claim against Landlord with respect to, any loss by theft or any other damage suffered or incurred by Tenant in connection with any unauthorized entry into the Premises or any other breach of security with respect to the Premises. Tenant shall be solely responsible for the personal safety of Tenant’s officers, employees, agents, contractors, guests and invitees while any such person is in, on or about the Premises and/or the Project. Tenant shall at Tenant’s cost obtain insurance coverage to the extent Tenant desires protection against such criminal acts.

 

34.                               Force Majeure. Landlord shall not responsible or liable for delays in the performance of its obligations hereunder when caused by, related to, or arising out of acts of God, strikes, lockouts, or other labor disputes, embargoes, quarantines, weather, national, regional, or local disasters, calamities, or catastrophes, inability to obtain labor or materials (or reasonable substitutes therefor) at reasonable costs or failure of, or inability to obtain, utilities necessary for performance, governmental restrictions, orders, limitations, regulations, or controls, national emergencies, delay in issuance or revocation of permits, enemy or hostile governmental action, terrorism, insurrection, riots, civil disturbance or commotion, fire or other casualty, and other causes or events beyond the reasonable control of Landlord (“Force Majeure”).

 

35.                               Brokers. Landlord and Tenant each represents and warrants that it has not dealt with any broker, agent or other person (collectively, “Broker”) in connection with this transaction and that no Broker brought about this transaction. Landlord and Tenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker, other than the broker, if any named in this Section 35, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction.

 

36.                               Limitation on Landlord’s Liability. NOTWITHSTANDING ANYTHING SET FORTH HEREIN OR IN ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT TO THE CONTRARY: (A) LANDLORD SHALL NOT BE LIABLE TO TENANT OR ANY OTHER PERSON FOR (AND TENANT AND EACH SUCH OTHER PERSON ASSUME ALL RISK OF) LOSS, DAMAGE OR INJURY, WHETHER ACTUAL OR CONSEQUENTIAL TO: TENANT’S PERSONAL PROPERTY OF EVERY KIND AND DESCRIPTION, INCLUDING, WITHOUT LIMITATION TRADE FIXTURES, EQUIPMENT, INVENTORY, SCIENTIFIC RESEARCH, SCIENTIFIC EXPERIMENTS, LABORATORY ANIMALS, PRODUCT, SPECIMENS, SAMPLES, AND/OR SCIENTIFIC, BUSINESS, ACCOUNTING AND OTHER RECORDS OF EVERY KIND AND DESCRIPTION KEPT AT THE PREMISES AND ANY AND ALL INCOME DERIVED OR DERIVABLE THEREFROM; (B) THERE SHALL BE NO PERSONAL RECOURSE TO LANDLORD FOR ANY ACT OR OCCURRENCE IN, ON OR ABOUT THE PREMISES OR ARISING IN ANY WAY UNDER THIS LEASE OR ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT WITH RESPECT TO THE SUBJECT MATTER HEREOF AND ANY LIABILITY OF LANDLORD HEREUNDER SHALL BE STRICTLY LIMITED SOLELY TO LANDLORD’S INTEREST IN THE PROJECT OR ANY PROCEEDS FROM SALE OR CONDEMNATION THEREOF

 

21











 

AND ANY INSURANCE PROCEEDS PAYABLE IN RESPECT OF LANDLORD’S INTEREST IN THE PROJECT OR IN CONNECTION WITH ANY SUCH LOSS; AND (C) IN NO EVENT SHALL ANY PERSONAL LIABILITY BE ASSERTED AGAINST ANY OF LANDLORD’S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS. UNDER NO CIRCUMSTANCES SHALL LANDLORD OR ANY OF LANDLORD’S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS BE LIABLE FOR INJURY TO TENANT’S BUSINESS OR FOR ANY LOSS OF INCOME OR PROFIT THEREFROM.

 

37.                               Severability. If any clause or provision of this Lease is illegal, invalid or unenforceable under present or future laws, then and in that event, it is the intention of the parties hereto that the remainder of this Lease shall not be affected thereby. It is also the intention of the parties to this Lease that in lieu of each clause or provision of this Lease that is illegal, invalid or unenforceable, there be added, as a part of this Lease, a clause or provision as similar in effect to such illegal, invalid or unenforceable clause or provision as shall be legal, valid and enforceable. This Lease, including the exhibits attached hereto, constitutes the entire agreement between Landlord and Tenant pertaining to the subject matter hereof and supersedes all prior agreements, understandings, letters of intent, negotiations, and discussions, whether oral or written, of the parties, and there are no warranties, representations, or other agreements, express or implied, made to either party by the other party in connection with the subject matter hereof except as specifically set forth herein or in the documents delivered pursuant hereto or in connection herewith.

 

38.                               Signs; Exterior Appearance. Tenant shall not, without the prior written consent of Landlord, which may be granted or withheld in Landlord’s sole discretion: (i) attach any awnings, exterior lights, decorations, balloons, flags, pennants, banners, painting or other projection to any outside wall of the Project, (ii) use any curtains, blinds, shades or screens other than Landlord’s standard window coverings, (iii) coat or otherwise sunscreen the interior or exterior of any windows, (iv) place any bottles, parcels, or other articles on the window sills, (v) place any equipment, furniture or other items of personal property on any exterior balcony, or (vi) paint, affix or exhibit on any part of the Premises or the Project any signs, notices, window or door lettering, placards, decorations, or advertising media of any type which can be viewed from the exterior of the Premises. Interior signs on doors and the directory tablet shall be inscribed, painted or affixed for Tenant by Landlord at the sole cost and expense of Tenant, and shall be of a size, color and type acceptable to Landlord. Nothing may be placed on the exterior of corridor walls or corridor doors other than Landlord’s standard lettering. The directory tablet shall be provided exclusively for the display of the name and location of tenants.

 

39.                                Right to Extend Term. Tenant shall have the right to extend the Term of this Lease upon the following terms and conditions:

 

(a)                                 Extension Right. Tenant shall have the right (“Extension Right”) to extend the term of this Lease for 5 years (“Extension Term”) on the same terms and conditions as this Lease (other than Base Rent) by giving Landlord written notice of its election to exercise each Extension Right at least 9 months prior, and no earlier than 12 months prior, to the expiration of the Base Term of this Lease.

 

(b)                                 Base Rent. Upon the commencement of the Extension Term, Base Rent shall be payable at the Market Rate (as defined below). Base Rent shall thereafter be adjusted on each anniversary of the commencement of the Extension Term by a percentage as mutually agreed to by Landlord and Tenant at the time the Market Rate is determined, As used herein, “Market Rate” shall mean the then market rental rate as mutually agreed to by Landlord and Tenant, which shall in no event be less than the Base Rent payable as of the date immediately preceding the commencement of the Extension Term increased by the Rent Adjustment Percentage multiplied by such Base Rent. In addition, Landlord may impose a market rent for the parking rights provided hereunder. If, on or before the date that is 120 days prior to the expiration of the Base Term of this Lease, Landlord and Tenant have not agreed on the Market Rate and the rent escalations during the Extension Term after negotiating in good

 

22











 

faith, Tenant shall be deemed to have waived any right to extend the Term of this Lease and the Extension Right shall terminate.

 

(c)                                  Right Personal. The Extension Right is personal to Tenant and is not assignable without Landlord’s consent, which may be granted or withheld in Landlord’s sole discretion separate and apart from any consent by Landlord to an assignment of Tenant’s interest in this Lease.

 

(d)                                 Exceptions. Notwithstanding anything set forth above to the contrary, the Extension Right shall not be in effect and Tenant may not exercise the Extension Right: (i) during any period of time that Tenant is in Default under any provision of this Lease; or (ii) if Tenant has been in Default under any provision of this Lease 3 or more times, regardless of whether the Defaults are cured, during the 12 month period immediately prior to the date that Tenant intends to exercise the Extension Right, regardless of whether the Defaults are cured.

 

(e)                                  No Extensions. The period of time within which the Extension Right may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Extension Right.

 

(f)                                   Termination. The Extension Right shall terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Extension Right, if, after such exercise, but prior to the commencement date of the Extension Term, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Extension Right to the date of the commencement of the Extension Term, regardless of whether such Defaults are cured.

 

40.                               Miscellaneous.

 

(a)                                 Notices. All notices or other communications between the parties shall be in writing and shall be deemed duly given upon delivery or refusal to accept delivery by the addressee thereof if delivered in person, or upon actual receipt if delivered by reputable overnight guaranty courier, addressed and sent to the parties at their addresses set forth above. Landlord and Tenant may from time to time by written notice to the other designate another address for receipt of future notices.

 

(b)                                 Joint and Several Liability. If and when included within the term “Tenant,” as used in this instrument, there is more than one person or entity, each shall be jointly and severally liable for the obligations of Tenant.

 

(c)                                  Financial Information. Tenant shall furnish Landlord with true and complete copies of (i) Tenant’s most recent audited annual financial statements within 90 days of the end of each of Tenant’s fiscal years during the Term, (ii) Tenant’s most recent unaudited quarterly financial statements within 45 days of the end of each of Tenant’s first three fiscal quarters of each of Tenant’s fiscal years during the Term, (iii) at Landlord’s request from time to time, updated business plans, including cash flow projections and/or pro forma balance sheets and income statements, all of which shall be treated by Landlord as confidential information belonging to Tenant, (iv) corporate brochures and/or profiles prepared by Tenant for prospective investors, and (v) any other financial information or summaries that Tenant typically provides to its lenders or shareholders.

 

(d)                                 Recordation. Neither this Lease nor a memorandum of lease shall be filed by or on behalf of Tenant in any public record. Landlord may prepare and file, and upon request by Landlord Tenant will execute, a memorandum of lease.

 

(e)                                  Interpretation. The normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Lease or any exhibits or amendments hereto. Words of any gender used in this Lease shall be held and construed to

 

23











 

include any other gender, and words in the singular number shall be held to include the plural, unless the context otherwise requires. The captions inserted in this Lease are for convenience only and in no way define, limit or otherwise describe the scope or intent of this Lease, or any provision hereof, or in any way affect the interpretation of this Lease.

 

(f)                                   Not Binding Until Executed. The submission by Landlord to Tenant of this Lease shall have no binding force or effect, shall not constitute an option for the leasing of the Premises, nor confer any right or impose any obligations upon either party until execution of this Lease by both parties.

 

(g)                                  Limitations on Interest. It is expressly the intent of Landlord and Tenant at all times to comply with applicable law governing the maximum rate or amount of any interest payable on or in connection with this Lease. If applicable law is ever judicially interpreted so as to render usurious any interest called for under this Lease, or contracted for, charged, taken, reserved, or received with respect to this Lease, then it is Landlord’s and Tenant’s express intent that all excess amounts theretofore collected by Landlord be credited on the applicable obligation (or, if the obligation has been or would thereby be paid in full, refunded to Tenant), and the provisions of this Lease immediately shall be deemed reformed and the amounts thereafter collectible hereunder reduced, without the necessity of the execution of any new document, so as to comply with the applicable law, but so as to permit the recovery of the fullest amount otherwise called for hereunder.

 

(h)                                 Choice of Law. Construction and interpretation of this Lease shall be governed by the internal laws of the state in which the Premises are located, excluding any principles of conflicts of laws.

 

(i)                                     Time. Time is of the essence as to the performance of Tenant’s obligations under this Lease.

 

{j)                                  OFAC. Tenant, and all beneficial owners of Tenant, are currently (i) in compliance with and shall at all times during the Term of this Lease remain in compliance with the regulations of the Office of Foreign Assets Control (“OFAC”) of the U.S. Department of Treasury and any statute, executive order, or regulation relating thereto (collectively, the “OFAC Rules”), (ii) not listed on, and shall not during the Term of this Lease be listed on, the Specially Designated Nationals and Blocked Persons List maintained by OFAC and/or on any other similar list maintained by OFAC or other governmental authority pursuant to any authorizing statute, executive order, or regulation, and (iii) not a person or entity with whom a U.S. person is prohibited from conducting business under the OFAC Rules.

 

(k)                                 Incorporation by Reference. All exhibits and addenda attached hereto are hereby incorporated into this Lease and made a part hereof. If there is any conflict between such exhibits or addenda and the terms of this Lease, such exhibits or addenda shall control.

 

(I)                                   No Accord and Satisfaction. No payment by Tenant or receipt by Landlord of a lesser amount than the monthly installment of Base Rent or any Additional Rent will be other than on account of the earliest stipulated Base Rent and Additional Rent, nor will any endorsement or statement on any check or letter accompanying a check for payment of any Base Rent or Additional Rent be an accord and satisfaction. Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance of such Rent or to pursue any other remedy provided in this Lease.

 

[ Signatures on next page ]

 

24











 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease under seal as of the day and year first above written.

 

	
 
    	
TENANT:
    
	
 
    	
 
    
	
 
    	
SUPERNUS   PHARMACEUTICALS, INC., a
   Delaware corporation
    
	
 
    	
 
    
	
 
    	
By:
    	
/s/ Jack Khatter
    
	
 
    	
Name:
    	
Jack Khatter
    
	
 
    	
Title:
    	
President and CEO
    
	
 
    	
 
    	
 
    
	
 
    	
LANDLORD:
    
	
 
    	
 
    
	
 
    	
ARE-1500 EAST GLIDE, LLC,
    
	
 
    	
a Delaware limited liability company
    
	
 
    	
 
    
	
 
    	
By:
    	
ARE-QRS Corp.,
    
	
 
    	
 
    	
a Maryland corporation,
    
	
 
    	
 
    	
its managing member
    
	
 
    	
 
    	
 
    
	
 
    	
 
    	
 
    	
 
    
	
 
    	
 
    	
By:
    	
/s/ Jackie Clem
    	
(SEAL)
    
	
 
    	
 
    	
Name:
    	
Jackie Clem
    	
 
    
	
 
    	
 
    	
Title:
    	
VP Real Estate Legal Affairs
    	
 
    
	
 
    	
 
    
	
 
    	
Copyright   © 2007, Alexandria Real Estate Equities, Inc. ALL
    
	
 
    	
RIGHTS   RESERVED. Confidential and Proprietary - Do Not
    
	
 
    	
Copy   or Distribute, Alexandria and the Alexandria Logo are
    
	
A L E X A N D R I A 
    	
 
    	
registered   trademarks of Alexandria Real Estate Equities, Inc.
    
							


 

25











 

EXHIBIT A TO LEASE

DESCRIPTION OF PREMISES

 

26











 

EXHIBIT B TO LEASE

DESCRIPTION OF PROJECT

 

All that lot or parcel of land located in the 4th Election District of Montgomery County, Maryland and described as follows:

 

Parcel I:

 

Lot numbered Five (5) in Block lettered “A” in the subdivision known as “Red Gate Industrial Park” as per plat thereof recorded in Plat Book 102 at Plat 11503, among the Land Records of Montgomery County, Maryland.

 

Parcel I.D. No.: 4-201-1762126

 

27











 

EXHIBIT C TO LEASE

WORK LETTER

 

THIS WORK LETTER (this “Work Letter”) is incorporated into that certain Lease (the “Lease”) dated as of February (   , 2013 by and between ARE-1500 EAST GUDE, LLC, a Delaware limited liability company (“Landlord”), and SUPERNUS PHARMACEUTICALS, INC., a Delaware corporation (“Tenant”). Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.

 

1.              General Requirements.

 

(a)    Tenant’s Authorized Representative. Tenant designates Frank G. Mottola (“Tenant’s Representative”) as the only person authorized to act for Tenant pursuant to this Work Letter. Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (“Communication”) from or on behalf of Tenant in connection with this Work Letter unless such Communication is in writing from Tenant’s Representative. Tenant may change Tenant’s Representative at any time upon not less than 5 business days advance written notice to Landlord.

 

(b)    Landlord’s Authorized Representative. Landlord designates Lawrence J. Diamond and Vincent Ciruzzi (either such individual acting alone, “Landlord’s Representative”) as the only persons authorized to act for Landlord pursuant to this Work Letter. Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or on behalf of Landlord in connection with this Work Letter unless such Communication is in writing from Landlord’s Representative. Landlord may change either Landlord’s Representative at any time upon not less than 5 business days advance written notice to Tenant.

 

(c)     Architects, Consultants and Contractors. Landlord and Tenant hereby acknowledge and agree that the architect (“TI Architect”) for the Tenant Improvements (as defined in Section 2(a) below), the general contractor and any subcontractors for the Tenant Improvements shall be selected by Tenant, subject to Landlord’s approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall be named a third party beneficiary of any contract entered into by Tenant with the TI Architect, any consultant, any contractor or any subcontractor, and of any warranty made by any contractor or any subcontractor.

 

2.              Tenant Improvements.

 

(a)    Tenant Improvements Defined. As used herein, “Tenant Improvements” shall mean all improvements to the Premises desired by Tenant of a fixed and permanent nature. Other than funding the TI Allowance (as defined below) as provided herein, Landlord shall not have any obligation whatsoever with respect to the finishing of the Premises for Tenant’s use and occupancy.

 

(b)    Tenant’s Space Plans. Tenant shall deliver to Landlord schematic drawings and outline specifications (“TI Design Drawings”) detailing Tenant’s requirements for the Tenant Improvements within 10 days of the date hereof. Not more than 15 days thereafter, Landlord shall deliver to Tenant the written objections, questions or comments of Landlord and the Ti Architect with regard to the TI Design Drawings. Tenant shall cause the TI Design Drawings to be revised to address such written comments and shall resubmit said drawings to Landlord for approval within 7 days thereafter. Such process shall continue until Landlord has approved the TI Design Drawings.

 

28









 

(c)     Working Drawings. Not later than 15 business days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlord’s receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the Ti Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).

 

(d)    Approval and Completion. If any dispute regarding the design of the Tenant Improvements is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable out of the TI Fund (as defined in Section 5(d) below), and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems (in which case Landlord shall make the final decision). Any changes to the TI Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof.

 

3.              Performance of the Tenant Improvements.

 

(a)    Commencement and Permitting of the Tenant Improvements. Tenant shall commence construction of the Tenant Improvements upon obtaining and delivering to Landlord a building permit (“TI Permit”) authorizing the construction of the Tenant Improvements consistent with the TI Construction Drawings approved by Landlord. The cost of obtaining the TI Permit shall be payable from the TI Fund. Landlord shall assist Tenant in obtaining the TI Permit. Prior to the commencement of the Tenant Improvements, Tenant shall deliver to Landlord a copy of any contract with Tenant’s contractors (including the TI Architect), and certificates of insurance from any contractor performing any part of the Tenant Improvement evidencing industry standard commercial general liability, automotive liability, “builder’s risk”, and workers’ compensation insurance. Tenant shall cause the general contractor to provide a certificate of insurance naming Landlord, Alexandria Real Estate Equities, Inc., and Landlord’s lender (if any) as additional insureds for the general contractor’s liability coverages required above.

 

(b)    Selection of Materials, Etc. Where more than one type of material or structure is indicated on the TI Construction Drawings approved by Tenant and Landlord, the option will be within Tenant’s reasonable discretion if the matter concerns the Tenant Improvements, and within Landlord’s sole and absolute subjective discretion if the matter concerns the structural components of the Building or any Building system.

 

(c)     Tenant Liability. Tenant shall be responsible for correcting any deficiencies or defects in the Tenant Improvements.

 

29











 

(d)    Substantial Completion. Tenant shall substantially complete or cause to be substantially completed the Tenant Improvements in a good and workmanlike manner, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature which do not interfere with the use of the Premises (“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of the Tenant Improvements, Tenant shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comport with good design, engineering, and construction practices which are not material; or (iii) to make reasonable adjustments for field deviations or conditions encountered during the construction of the Tenant Improvements.

 

4.              Changes. Any changes requested by Tenant to the Tenant Improvements after the delivery and approval by Landlord of the TI Design Drawings, shall be requested and instituted in accordance with the provisions of this Section 4 and shall be subject to the written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed.

 

(a)    Tenant’s Right to Request Changes. If Tenant shall request changes (“Changes”), Tenant shall request such Changes by notifying Landlord in writing in substantially the same form as the AIA standard change order form (a “Change Request”), which Change Request shall detail the nature and extent of any such Change. Such Change Request must be signed by Tenant’s Representative. Landlord shall review and approve or disapprove such Change Request within 10 business days thereafter, provided that Landlord’s approval shall not be unreasonably withheld, conditioned or delayed.

 

(b)    Implementation of Changes. If Landlord approves such Change and Tenant deposits with Landlord any Excess TI Costs if applicable (as defined in Section 5(d) below) required in connection with such Change, Tenant may cause the approved Change to be instituted. If any TI Permit modification or change is required as a result of such Change, Tenant shall promptly provide Landlord with a copy of such TI Permit modification or change.

 

5.              Costs.

 

(a)    Budget For Tenant Improvements. Before the commencement of construction of the Tenant Improvements, Tenant shall obtain a detailed breakdown, by trade, of the costs incurred or that will be incurred, in connection with the design and construction of the Tenant Improvements (“Budget”), and deliver a copy of the Budget to Landlord for Landlord’s approval, which shall not be unreasonably withheld or delayed. The Budget shall be based upon the TI Construction Drawings approved by Landlord. If the Budget is greater than the TI Allowance, Tenant shall deposit with Landlord the difference, in cash, prior to the commencement of construction of the Tenant Improvements, for disbursement by Landlord as described in Section 5(d).

 

(b)    TI Allowance.  Landlord shall provide to Tenant a tenant improvement allowance(“TI Allowance”) of $45 per rentable square foot of the Premises, or $535,500 in the aggregate. The TI Allowance shall be disbursed in accordance with this Work Letter. Tenant shall have no right to the use or benefit (including any reduction to Base Rent) of any portion of the TI Allowance not required for the construction of (i) the Tenant Improvements described in the TI Construction Drawings approved pursuant to Section 2(d) or (ii) any Changes pursuant to Section 4; provided, however, that if and to the extent any TI Allowance remains after the completion of the Tenant Improvements, Tenant shall have the right to use such remaining balance during the balance of the Base Term to defray the cost of any subsequent Alterations made to the Premises in accordance with the terms and conditions of the Lease. Tenant shall have no right to any portion

 

30











 

of the TI Allowance that is not disbursed before the expiration or earlier termination of the Base Term.

 

(c)     Costs Includable in Ti Fund. The TI Fund shall be used solely for the payment of design, permits and construction costs in connection with the construction of the Tenant Improvements, including, without limitation, the cost of electrical power and other utilities used in connection with the construction of the Tenant Improvements, the cost of preparing the TI Design Drawings and the TI Construction Drawings, all costs set forth in the Budget, including the cost of Changes, and Tenant’s voice or data cabling (collectively, “TI Costs”). Notwithstanding anything to the contrary contained herein, the TI Fund shall not be used to purchase any furniture, personal property or other non-Building system materials or equipment, including, but not be limited to, non-ducted biological safety cabinets and other scientific equipment not incorporated into the Tenant Improvements.

 

(d)    Excess TI Costs. Landlord shall have no obligation to bear any portion of the cost of any of the Tenant Improvements except to the extent of the TI Allowance. If at any time and from time-to-time, the remaining TI Costs under the Budget exceed the remaining unexpended TI Allowance, Tenant shall deposit with Landlord, as a condition precedent to Landlord’s obligation to complete the Tenant Improvements, 100% of the then current TI Cost in excess of the remaining TI Allowance (“Excess TI Costs”). If Tenant fails to deposit, or is late in depositing any Excess TI Costs with Landlord, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease. The TI Allowance and Excess TI Costs is herein referred to as the “TI Fund.” Funds deposited by Tenant shall be the first thereafter disbursed to pay TI Costs. Notwithstanding anything to the contrary set forth in this Section 5(d), Tenant shall be fully and solely liable for TI Costs and the cost of Minor Variations in excess of the TI Allowance. If upon Substantial Completion of the Tenant Improvements and the payment of all sums due in connection therewith there remains any undisbursed portion of the TI Fund, Tenant shall be entitled to such undisbursed TI Fund solely to the extent of any Excess TI Costs deposit Tenant has actually made with Landlord.

 

(e)     Payment for TI Costs. During the course of design and construction of the Tenant Improvements, Landlord shall pay TI Costs once a month against a draw request in Landlord’s standard form, containing such certifications, lien waivers (including a conditional lien release for each progress payment and unconditional lien releases for the prior month’s progress payments), inspection reports and other matters as Landlord customarily obtains, to the extent of Landlord’s approval thereof for payment, no later than 30 days following receipt of such draw request. Upon completion of the Tenant Improvements (and prior to any final disbursement of the TI Fund), Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and first tier subcontractors who did the work and final, unconditional lien waivers from all such contractors and first tier subcontractors; (ii) as-built plans (one copy in print format and two copies in electronic CAD format) for such Tenant Improvements;  (iii) a certification of substantial completion in Form AIA G704, (iv) a certificate of occupancy for the Premises; and (v) copies of all operation and maintenance manuals and warranties affecting the Premises.

 

6.              Miscellaneous.

 

(a)    Consents. Whenever consent or approval of either party is required under this Work Letter, that party shall not unreasonably withhold, condition or delay such consent or approval, except as may be expressly set forth herein to the contrary.

 

31











 

(b)    Modification. No modification, waiver or amendment of this Work Letter or of any of its conditions or provisions shall be binding upon Landlord or Tenant unless in writing signed by Landlord and Tenant.

 

32











 

EXHIBIT D TO LEASE

ACKNOWLEDGMENT OF COMMENCEMENT DATE

 

This ACKNOWLEDGMENT OF COMMENCEMENT DATE is made as of this               day of                  , 2013, between ARE-1500 EAST GUDE, LLC, a Delaware limited liability company (“Landlord”), and SUPERNUS PHARMACEUTICALS, INC., a Delaware corporation (“Tenant”), and is attached to and made a part of. the Lease dated as of February    , 2013 (“Lease”), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.

 

Landlord and Tenant hereby acknowledge and agree that the Commencement Date of the Base Term of the Lease is                , 2013, the Rent Commencement Date is                  , 2013, and the expirartion date of the Base Term of the Lease shall be midnight on                                      In case of a conflict between the terms of the Lease and the terms of this Acknowledgement of Commencement Date, this Acknowledgement of Commencement Date shall control for all purposes.

 

IN WITNESS WHEREOF, Landlord and Tenant have executed this ACKNOWLEDGMENT OF COMMENCEMENT DATE under seal to be effective on the date first above written.

 

	
 
    	
TENANT:
    
	
 
    	
 
    
	
 
    	
SUPERNUS   PHARMACEUTICALS, INC., a Delaware corporation
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
By:
    	
(SEAL)
    
	
 
    	
Name:
    	
 
    
	
 
    	
Title:
    	
 
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
LANDLORD:
    
	
 
    	
 
    
	
 
    	
ARE-1500   EAST GUDE, LLC,
    
	
 
    	
a   Delaware limited liability company
    
	
 
    	
 
    
	
 
    	
By:
    	
ARE-QRS   Corp.,
    
	
 
    	
 
    	
a   Maryland corporation,
    
	
 
    	
 
    	
its   managing member
    
	
 
    	
 
    
	
 
    	
 
    
	
 
    	
 
    	
By:
    	
(SEAL)
    
	
 
    	
 
    	
Name:
    	
 
    
	
 
    	
 
    	
Title:
    	
 
    
	
 
    	
 
    
	
 
    	
Copyright   © 2007, Alexandria Real Estate Equities, Inc. ALL 
    
	
 
    	
RIGHTS   RESERVED. Confidential and Proprietary - Do Not 
    
	
 
    	
Copy   or Distribute. Alexandria and the Alexandria Logo are
    
	
ALEXANDRIA
    	
 
    	
registered   trademarks of Alexandria Real Estate Equities, Inc.
    
					


 

33











 

EXHIBIT E TO LEASE

 

Rules and Regulations

 

1.                                      The sidewalk, entries, and driveways of the Project shall not be obstructed by Tenant, or any Tenant Party, or used by them for any purpose other than ingress and egress to and from the Premises.

 

2.                                      Tenant shall not place any objects, including antennas, outdoor furniture, etc., in the parking areas, landscaped areas or other areas outside of its Premises, or on the roof of the Project.

 

3.                                      Except for animals assisting the disabled, no animals shall be allowed in the offices, halls, or corridors in the Project.

 

4.                                      Tenant shall not disturb the occupants of the Project or adjoining buildings by the use of any radio or musical instrument or by the making of loud or improper noises.

 

5.                                      If Tenant desires telegraphic, telephonic or other electric connections in the Premises, Landlord or its agent will direct the electrician as to where and how the wires may be introduced; and, without such direction, no boring or cutting of wires will be permitted. Any such installation or connection shall be made at Tenant’s expense.

 

6.                                      Tenant shall not install or operate any steam or gas engine or boiler, or other mechanical apparatus in the Premises, except as specifically approved in the Lease. The use of oil, gas or inflammable liquids for heating, lighting or any other purpose is expressly prohibited. Explosives or other articles deemed extra hazardous shall not be brought into the Project.

 

7.                                      Parking any type of recreational vehicles is specifically prohibited on or about the Project. Except for the overnight parking of operative vehicles, no vehicle of any type shall be stored in the parking areas at any time. In the event that a vehicle is disabled, it shall be removed within 48 hours. There shall be no “For Sale” or other advertising signs on or about any parked vehicle. All vehicles shall be parked in the designated parking areas in conformity with all signs and other markings. All parking will be open parking, and no reserved parking, numbering or lettering of individual spaces will be permitted except as specified by Landlord.

 

8.                                      Tenant shall maintain the Premises free from rodents, insects and other pests.

 

9.                                      Landlord reserves the right to exclude or expel from the Project any person who, in the judgment of Landlord, is intoxicated or under the influence of liquor or drugs or who shall in any manner do any act in violation of the Rules and Regulations of the Project.

 

10.                               Tenant shall not cause any unnecessary labor by reason of Tenant’s carelessness or indifference in the preservation of good order and cleanliness. Landlord shall not be responsible to Tenant for any loss of property on the Premises, however occurring, or for any damage done to the effects of Tenant by the janitors or any other employee or person.

 

11.                               Tenant shall give Landlord prompt notice of any defects in the water, lawn sprinkler, sewage, gas pipes, electrical lights and fixtures, heating apparatus, or any other service equipment affecting the Premises.

 

12.                               Tenant shall not permit storage outside the Premises, including without limitation, outside storage of trucks and other vehicles, or dumping of waste or refuse or permit any harmful materials to be placed in any drainage system or sanitary system in or about the Premises.

 

34











 

13.                               All moveable trash receptacles provided by the trash disposal firm for the Premises must be kept in the trash enclosure areas, if any, provided for that purpose.

 

14.                               No auction, public or private, will be permitted on the Premises or the Project.

 

15.                               No awnings shall be placed over the windows in the Premises except with the prior written consent of Landlord.

 

16.                               The Premises shall not be used for lodging, sleeping or cooking or for any immoral or illegal purposes or for any purpose other than that specified in the Lease. No gaming devices shall be operated in the Premises.

 

17.                               Tenant shall ascertain from Landlord the maximum amount of electrical current which can safely be used in the Premises, taking into account the capacity of the electrical wiring in the Project and the Premises and the needs of other tenants, and shall not use more than such safe capacity. Landlord’s consent to the installation of electric equipment shall not relieve Tenant from the obligation not to use more electricity than such safe capacity.

 

18.                               Tenant assumes full responsibility for protecting the Premises from theft, robbery and pilferage.

 

19.                               Tenant shall not install or operate on the Premises any machinery or mechanical devices of a nature not directly related to Tenant’s ordinary use of the Premises and shall keep all such machinery free of vibration, noise and air waves which may be transmitted beyond the Premises.

 

35











 

EXHIBIT F TO LEASE

TENANT’S PERSONAL PROPERTY

 

None except as set forth below:

 

NONE

 

36