[Cite as Crowe Ents., Inc. v. Amicon Med. Group, Inc., 2014-Ohio-11.]

IN THE COURT OF APPEALS

ELEVENTH APPELLATE DISTRICT 

PORTAGE COUNTY, OHIO 

CROWE ENTERPRISE, INC., : O P I N I O N 

 Plaintiff-Appellee, :

CASE NO. 2013-P-0031

 - vs - :

AMICON MEDICAL GROUP, INC., :

 Defendant-Appellant. :

Civil Appeal from the Portage County Court of Common Pleas, Case No. 2008 CV 

001988. 

Judgment: Reversed and remanded. 

Jared L. Wilson, 250 South Prospect Street, Ravenna, OH 44266 (For PlaintiffAppellee). 

Gary L. Lieberman, Gary L. Lieberman Co., LPA, 30195 Chagrin Boulevard, Suite 300, 

Pepper Pike, OH 44124 (For Defendant-Appellant). 

THOMAS R. WRIGHT, J. 

{¶1} This appeal is from the Portage County Court of Common Pleas. The trial 

court determined that defendant-appellant Amicon Medical Group, Inc. (“Amicon”) 

could not recover for appellee Crowe Enterprises, Inc.’s (“Crowe Enterprises”) alleged 

anticipatory repudiation of another contract because (1) Amicon did not follow the 

claim-dispute mechanism in that contract and (2) there was no anticipatory repudiation. 

Amicon timely appeals. For the following reasons, we reverse and remand for further 

proceedings. 
 2

{¶2} This case originally arose out of Crowe Enterprises’, a masonry 

subcontractor, efforts to recover approximately $20,000 from Amicon, a general 

contractor in construction, from a previous contract between the parties. At trial, the 

parties stipulated that Amicon was liable to Crowe Enterprises for $19,675 in regard to 

this previous contract. However before trial, in response to Crowe Enterprises’ 

complaint, Amicon filed a multiple-count counterclaim alleging that Crowe breached a 

masonry contract with Amicon regarding the construction of the SAGA Medical Building 

in Middleburg Heights (“the SAGA contract”) and that Amicon incurred $38,148.20 in 

damages from having to hire another subcontractor for the masonry work. This appeal 

concerns the dispute around the SAGA contract. 

{¶3} On April 1, 2008, Amicon and Crowe Enterprises entered into a contract 

where Crowe Enterprises would perform the masonry work for Amicon’s construction 

projection regarding the SAGA Medical Building. The contract indicates that time was 

of the essence; however, no start date was put into the contract. According to Doug 

Crowe, vice president of Crowe Enterprises, performance of the contract was 

supposed to commence in May of 2008 based off of previous conversations he had 

with Amicon agents leading up to the signing of the contract. Doug Crowe testified that 

he relied upon the May start time given the limited amount of crews Crowe possessed. 

When it became apparent that the project was going to be delayed, Doug Crowe 

alleged he made several attempts with Amicon agents to obtain an update on when the 

masonry work would start without answer. Though Doug Crowe acknowledged that 

delays of up to two to three weeks are typical in construction, Crowe Enterprises would 

not begin work on the SAGA contract until late July or early August 2008. 
 3

{¶4} According to Bruce Baum, president of Amicon, work was supposed to 

commence in July of 2008. Baum further testified that he had several oral 

conversations over the telephone about the start date of Crowe’s work on the SAGA 

contract. However, when Amicon had to delay construction and Baum was not aware 

of whether a revised schedule was sent to Crowe Enterprises. 

{¶5} Crowe Enterprises started some preliminary work on the SAGA contract at 

some point in either mid or late July. Because Crowe Enterprises had other projects 

ongoing in the fall and a shortage of personnel to work the SAGA contract, Crowe 

Enterprises determined it could not continue working on the SAGA contract. On or 

about August 1, 2008, Crowe wrote an e-mail to Amicon stating that: 

{¶6} “Bruce, 

{¶7} “We are not going to be able to get to this job by Monday. We need to 

walk away from this project, sorry I talked to Jason Mamrak w/ Mamrak’s Masonry, he 

sounds like he has a good Number and a handle on the job. The crew we had pricing 

got another job yesterday and can’t make it anyway. (warren jones masonry) I think 

you’ll get the best service from using him and the $ are very close. We will walk away 

and not expect anything for the labor already completed. The material already 

delivered will stay with the job and billed to whoever is paying for the material, you can 

handle that with Bierce. 

{¶8} “I hope this will not hurt our relationship for future projects, but I 

understand 

{¶9} “Doug Crowe.” 

{¶10} On August 1, 2008, Mike Jones, an employee of Amicon replied that: 

{¶11} “Hey Doug 
 4

{¶12} “We understand you got swamped. Thanks for the honesty. I[t] happens 

to us all at times. Don’t worry you are still on our bid list. 

{¶13} “* * * 

{¶14} “Thanks 

{¶15} “Mike Jones.” 

{¶16} A trial was held on October 15, 2010. The parties stipulated to the 

jurisdiction of the court. In regard to the e-mail exchange, Crowe argued the e-mail 

exchange was a mutual rescission of the contract, while Amicon argued the e-mail 

exchange was indicative of anticipatory repudiation by Crowe. In Crowe’s closing 

argument brief, it claimed for the first time that Amicon’s counterclaim was barred 

because it did not comply with the claim dispute mechanism in the SAGA contract. 

The claim dispute mechanism requires a party that seeks litigation under the contract 

to, among other things, negotiate a solution among themselves, explore alternative 

dispute resolution, and then file suit in the Circuit Court of the Judicial Circuit in and for 

Cuyahoga County, Ohio. 

{¶17} The magistrate dismissed the counterclaim on the grounds that the failure 

to comply with the claim dispute mechanism barred the counterclaim. The magistrate 

also found that the claim for the anticipatory repudiation was without merit because 

Crowe had started performance of the contract. The trial court made similar findings as 

the magistrate and adopted the magistrate’s findings over Amicon’s objections. 

{¶18} Because appellant’s first three assignments of error seek the reversal of 

the application of the claim-dispute mechanism provided in the SAGA Contract, we will 

consolidate them in our review. As Amicon’s first, second, and third assignments of 

error, Amicon alleges that: 
 5

{¶19} “[1.] Crowe’s Stipulation that the Court had Jurisdiction to Hear Amicon’s 

Claim and Crowe’s allowing the case to be Tried on the Merits Constituted a Waiver of 

the Claims-Dispute Provision in its Entirety. 

{¶20} “[2.] The Trial Court Cannot Find Amicon Waived Enforcement of the 

Claims-Dispute Provision in the Fairlawn Contract Without Finding that Crowe Waived 

Enforcement of the Claims-Dispute Provision in the SAGA Contract. 

{¶21} “[3.] The Claims-Dispute Provision was Inapplicable To Amicon’s Claim 

Because There Was to be No Performance Under the SAGA Contract and No 

Payments were to be Made Under the SAGA Contract.” 

{¶22} Because the question of waiver is usually a fact-driven issue, we review 

the trial court’s decision for an abuse of discretion. Ohio Bell Telephone v. Central 

Transport, 8th Dist. Cuyahoga No. 96472, 2011-Ohio-6161, ¶17. The phrase “abuse of 

discretion” indicates the trial court's attitude in issuing its decision was arbitrary, 

unreasonable, or otherwise unconscionable. Blakemore v. Blakemore, 5 Ohio St.3d 

217, 219 (1983). Should a question of law be raised, however, we will review those 

issues de novo. Wren v. Tutolo, 11th Dist. Geauga No. 2012-G-3104, 2013-Ohio-995, 

¶8. 

{¶23} To prove waiver of an arbitration clause or other alternate dispute 

resolution clauses in contracts, the opposing party must show (1) knowledge of the 

existence of the right being waived and (2) conduct that is inconsistent with the 

enforcement of that right. Hogan v. Cincinnati Fin. Corp., 11th Dist. Trumbull No. 2003-

T-0034, 2004-Ohio-3331 ¶23. To determine whether a party has engaged in conduct 

that is inconsistent with the enforcement of that right we look at the totality of the 
 6

circumstances. Glenmoore Builders v. Kennedy, 11th Dist. Portage No. 2001-P-0007, 

2001 Ohio App. LEXIS 5449, at *10 (December 7, 2001). 

{¶24} Active participation in litigation “evincing an acquiescence to proceeding in 

a judicial rather than arbitration forum” has been found to constitute a waiver. Griffith v. 

Linton, 130 Ohio App.3d 746, 752 (10th Dist.1998) (quoting Envirex, Inc. v. K.H. 

Schussler Fur Umwelttechnik Gmbh, 832 F. Supp. 1293, 1295 (E.D. Wis. 1993)). 

Though there is much debate about when a party becomes an active participant in 

litigation, this court has previously determined that filing a motion for summary 

judgment will waive an arbitration clause because a motion for summary judgment 

“places the dispute squarely before the court for resolution on the merits and 

demonstrates an election to proceed with litigation as opposed to arbitration.” Hogan, 

¶25 (quoting Griffith v. Linton, 130 Ohio App. 3d 746, 753 (10th Dist.1998)). 

{¶25} Here, the SAGA contract contains a claim dispute mechanism that 

requires parties before filing suit to give notice of the complaint a party has against 

another, attempt to negotiate a resolution to the claim, and explore alternate dispute 

resolutions including arbitration. Crowe was aware of this provision and yet proceeded 

to trial on the merits of Amicon’s counterclaim without ever raising the issue of 

Amicon’s noncompliance with the claim dispute mechanism until the end of trial.1

 By 

failing to raise the issue earlier, Crowe waived any right they had to enforce the claimdispute resolution against Amicon. 

{¶26} Though we recognize this claim dispute mechanism is not strictly speaking 

an arbitration clause, the principles regarding waiver of arbitration apply with equal 

 

1. The trial court, in its April 3, 2012 Order and Journal Entry claim that Crowe first raised the issue in the 

October 12, 2010 pre-trial brief. After searching through that brief, however, we find nothing that would 

put Amicon on notice of the need to respond. 
 7

force. When the parties proceed to trial on a claim that is subject to a claim dispute 

mechanism in a contract, the enforcement of that claim dispute mechanism is waived. 

Like a motion for summary judgment, placing the merits of the claim before the 

factfinder unequivocally indicates a willingness to be bound by its findings, 

notwithstanding the claim dispute mechanism. 

{¶27} The first assignment of error is well-taken. In light of our ruling on the first 

assignment of error, the second and third assignments of error are moot. 

{¶28} As its fourth assignment of error, Amicon alleges that: 

{¶29} “Crowe’s Conduct and Statements Regarding the SAGA Contract 

Constituted an Anticipatory Repudiation of the SAGA Contract.” 

{¶30} Under the civil manifest weight of the evidence standard, “[j]udgments 

supported by some competent, credible evidence going to all the essential elements of 

the case will not be reversed by a reviewing court as being against the manifest weight 

of the evidence.” State v. Wilson, 113 Ohio St.3d 382, 2007-Ohio-2202 ¶24 (quoting 

C.E. Morris Co. v. Foley Constr. Co., 54 Ohio St.2d 279 (1978), syllabus). “A finding of 

an error in law is a legitimate ground for reversal, but a difference of opinion on 

credibility of witnesses and evidence is not.” Id. (quoting Seasons Coal Co., Inc. v. 

Cleveland, 10 Ohio St.3d 77, 81 (1984)). 

{¶31} An anticipatory repudiation of a contract occurs when one party to the 

contract refuses to perform under the contract's terms before the time for performance 

has arrived. Southeast Land Development, Ltd. v. Primrose Management, L.L.C., 193 

Ohio App.3d 465, 2011-Ohio-2341, ¶7 (3d Dist.) (citing Blake Homes, Ltd. v 

FirstEnergy Corp., 173 Ohio App.3d 230, 2007-Ohio-4606, ¶73 (6th Dist.)). 
 8

{¶32} “An anticipatory breach of contract must be an unequivocal repudiation of 

the contract. [Sentinel Consumer Prods., Inc. v. Mills, Hall, Walborn & Assocs., Inc., 

110 Ohio App. 3d 211 (1996).] A mere request for a change in terms or for 

cancellation does not constitute a repudiation. * * * Similarly, a mere expression of 

doubt as to willingness or ability to perform is insufficient to constitute repudiation of a 

contract.” Southeast Land Dev., Ltd. v. Primrose Mgmt., LLC, supra (other citations 

omitted). Ultimately, "[w]hether a party has repudiated a contract or merely expressed 

doubt as to willingness to perform is a question of fact.” Farmers Comm. Co. v. Burks, 

130 Ohio App.3d 158, 172, (1998). 

{¶33} In the present matter, the magistrate found that there was no anticipatory 

repudiation based on the fact that work had already been performed. In Doug Crowe’s 

e-mail to Amicon, Crowe writes that “[w]e need to walk away from this project” and later 

reaffirms his earlier statement by saying “[w]e will walk away and not expect anything 

for the labor already completed.” Because Doug Crowe’s e-mail, as well as both 

parties’ testimony, indicated Crowe had started performance on the SAGA contract 

before informing that it would not further perform, Crowe could not anticipatory 

repudiate the contract as a matter of law. Anticipatory repudiation can only occur 

before the performance of the contract, not after. 

{¶34} Where a breach of contract occurs, however, focusing on the time and 

legal characterization of that breach is academic and avoids the central issues of the 

litigation: namely, whether a breach occurred and, if so, what are the damages. 

Unfortunately, we cannot yet decide whether there was a breach of contract due to 

insufficient findings by the trial court. It is undisputed that (1) there was a contract 

between Amicon and Crowe Enterprises, (2) Crowe Enterprises began some work on 
 9

the contract in late July or early August 2008, (3) Crowe Enterprises ceased performing 

work on the contract, and (4) Amicon alleges damages resulting from Crowe’s 

cessation of activities on the SAGA contract. Whether this conduct amounted to a 

breach of contract is something the trial court has not yet decided. Indeed, even 

though the trial court has found that there was no mutual rescission of or an accord and 

satisfaction relating to the SAGA contract, we cannot rule out the possibility that Crowe 

Enterprises has further defenses regarding their alleged breach of the SAGA contract 

that have not been addressed. 

{¶35} The fourth assignment of error is overruled to the extent that no 

anticipatory breach was found. 

{¶36} Accordingly the judgment of the Portage County Court of Common Pleas 

is reversed and we remand for further proceedings. As the parties have waived the 

claim dispute mechanism in the SAGA contract, the trial court should determine on 

remand whether there was a breach of contract, assess Crowe Enterprises’ defenses, 

and award damages, if any. 

CYNTHIA WESTCOTT RICE, J., 

COLLEEN MARY O’TOOLE, J., 

concur.