30092 Federal Register / Vol. 74, No. 120 / Wednesday, June 24, 2009 / Notices 

DEPARTMENT OF DEFENSE 

GENERAL SERVICES 

ADMINISTRATION 

NATIONAL AERONAUTICS AND 

SPACE ADMINISTRATION 

[OMB Control No. 9000–0074] 

Federal Acquisition Regulation; 

Information Collection; Contract 

Funding—Limitation of Costs/Funds 

AGENCIES: Department of Defense (DOD), 

General Services Administration (GSA), 

and National Aeronautics and Space 

Administration (NASA). 

ACTION: Notice of request for comments 

regarding the reinstatement of a 

previously existing OMB clearance. 

SUMMARY: Under the provisions of the 

Paperwork Reduction Act of 1995 (44 

U.S.C. Chapter 35), the Federal 

Acquisition Regulation (FAR), 

Regulatory Secretariat will be 

submitting to the Office of Management 

and Budget (OMB) a request to review 

and approve an extension of a currently 

approved information collection 

requirement concerning Contract 

Funding—Limitation of Costs/Funds. 

Public comments are particularly 

invited on: Whether this collection of 

information is necessary; whether it will 

have practical utility; whether our 

estimate of the public burden of this 

collection of information is accurate, 

and based on valid assumptions and 

methodology; ways to enhance the 

quality, utility, and clarity of the 

information to be collected; and ways in 

which we can minimize the burden of 

the collection of information on those 

who are to respond, through the use of 

appropriate technological collection 

techniques or other forms of information 

technology. 

DATES: Submit comments on or before 

August 24, 2009. 

ADDRESSES: Submit comments regarding 

this burden estimate or any other aspect 

of this collection of information, 

including suggestions for reducing this 

burden, to: General Services 

Administration, Regulatory Secretariat 

(VPR), 1800 F Street NW., Room 4041, 

Washington, DC 20405. Please cite OMB 

Control No. 9000–0074, Contract 

Funding—Limitation of Costs/Funds, in 

all correspondence. 

FOR FURTHER INFORMATION CONTACT: Mr. 

Edward Chambers, Procurement 

Analyst, Contract Policy Division, GSA, 

(202) 501–3221. 

A. Purpose 

Firms performing under Federal costreimbursement contracts are required to 

notify the contracting officer in writing 

whenever they have reason to believe— 

(1) The costs the contractors expect to 

incur under the contracts in the next 60 

days, when added to all costs previously 

incurred, will exceed 75 percent of the 

estimated cost of the contracts; or 

(2) The total cost for the performance 

of the contracts will be greater or 

substantially less than estimated. As a 

part of the notification, the contractors 

must provide a revised estimate of total 

cost. 

B. Annual Reporting Burden 

Respondents: 53,456. 

Responses per Respondent: 1. 

Annual Responses: 53,456. 

Hours per Response: .5. 

Total Burden Hours: 26,728. 

Obtaining Copies of Proposals: 

Requesters may obtain a copy of the 

information collection documents from 

the General Services Administration, 

Regulatory Secretariat (VPR), 1800 F 

Street, NW., Room 4041, Washington, 

DC 20405, telephone (202) 501–4755. 

Please cite OMB Control No. 9000–0074, 

Contract Funding—Limitation of Costs/ 

Funds, in all correspondence. 

Dated: June 18, 2009. 

Al Matera, 

Director, Office of Acquisition Policy. 

[FR Doc. E9–14831 Filed 6–23–09; 8:45 am] 

BILLING CODE 6820–EP–P 

DEPARTMENT OF DEFENSE 

GENERAL SERVICES 

ADMINISTRATION 

NATIONAL AERONAUTICS AND 

SPACE ADMINISTRATION 

[OMB Control No. 9000–0058] 

Federal Acquisition Regulation; 

Information Collection; Schedules for 

Construction Contracts 

AGENCIES: Department of Defense (DOD), 

General Services Administration (GSA), 

and National Aeronautics and Space 

Administration (NASA). 

ACTION: Notice of request for comments 

regarding the reinstatement of a 

previously existing OMB clearance. 

SUMMARY: Under the provisions of the 

Paperwork Reduction Act of 1995 (44 

U.S.C. Chapter 35), the Federal 

Acquisition Regulation (FAR), 

Regulatory Secretariat will be 

submitting to the Office of Management 

and Budget (OMB) a request to review 

and approve an extension of a currently 

approved information collection 

requirement concerning Schedules for 

Construction Contracts. 

Public comments are particularly 

invited on: Whether this collection of 

information is necessary; whether it will 

have practical utility; whether our 

estimate of the public burden of this 

collection of information is accurate, 

and based on valid assumptions and 

methodology; ways to enhance the 

quality, utility, and clarity of the 

information to be collected; and ways in 

which we can minimize the burden of 

the collection of information on those 

who are to respond, through the use of 

appropriate technological collection 

techniques or other forms of information 

technology. 

DATES: Submit comments on or before 

August 24, 2009. 

ADDRESSES: Submit comments regarding 

this burden estimate or any other aspect 

of this collection of information, 

including suggestions for reducing this 

burden, to: General Services 

Administration, Regulatory Secretariat 

(VPR), 1800 F Street, NW., Room 4041, 

Washington, DC 20405. Please cite OMB 

Control No. 9000–0058, Schedules for 

Construction Contracts, in all 

correspondence. 

FOR FURTHER INFORMATION CONTACT: Mr. 

Ernest Woodson, Procurement Analyst, 

Contract Policy Division, GSA, (202) 

501–3775. 

A. Purpose 

Federal construction contractors may 

be required to submit schedules, in the 

form of a progress chart, showing the 

order in which the contractor proposes 

to perform the work. Actual progress 

shall be entered on the chart as directed 

by the contracting officer. This 

information is used to monitor progress 

under a Federal construction contract 

when other management approaches for 

ensuring adequate progress are not used. 

B. Annual Reporting Burden 

Respondents: 2,600. 

Responses per Respondent: 2. 

Annual Responses: 5,200. 

Hours per Response: 1. 

Total Burden Hours: 5,200. 

Obtaining Copies of Proposals: 

Requesters may obtain a copy of the 

information collection documents from 

the General Services Administration, 

Regulatory Secretariat (VPR), 1800 F 

Street, NW., Room 4041, Washington, 

DC 20405, telephone (202) 501–4755. 

Please cite OMB Control No. 9000–0058, 

Schedules for Construction Contracts, in 

all correspondence. 

Dated: June 18, 2009. 

Al Matera, 

Director, Office of Acquisition Policy. 

[FR Doc. E9–14829 Filed 6–23–09; 8:45 am] 

BILLING CODE 6820–EP–P