IN THE COURT OF APPEALS OF THE STATE OF WASHINGTON

DIVISION THREE

BRASHEAR ELECTRIC, Inc., a 

Washington Corporation,

Appellant,

v.

NORCAL PROPERTIES, LLC, a 

Washington limited liability company; 

COLUMBIA STATE BANK, a 

Washington chartered bank; BLUE 

BRIDGE PROPERTIES, LLC, a 

Washington limited liability company,

Respondents,

WHEATLAND BANK, a Washington 

chartered bank; NELSON ROOFING 

ENTERPRISES, INC., an Oregon 

Corporation d/b/a PALMER ROOFING 

COMPANY,

Defendants.

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

)

No. 37379-7-III

PUBLISHED OPINION

LAWRENCE-BERREY, J. — To secure payment for an “improvement” of real 

property, RCW 60.04.091 requires a contractor to record a notice of a claim of lien not

later than 90 days after ceasing to furnish labor, professional services, materials, or

equipment, or the last date on which employee benefit contributions were due. 

“Improvement” includes repairing real property. 

FILED

MARCH 11, 2021

In the Office of the Clerk of Court

WA State Court of Appeals, Division III
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

2

The question we answer today is whether the 90 days to record a claim of lien is 

extended by a contractor performing warranty work—that is, work performed after 

substantial completion to correct nonconforming work. We strictly construe “repairing” 

to exclude a contractor’s correction of its own work and conclude that performing 

warranty work does not extend the 90 days to record a claim of lien. 

FACTS

Norcal Properties, LLC and Blue Bridge Properties, LLC own adjacent properties. 

Under separate contracts, the owners hired prime contractor Vandervert Construction, 

Inc. to construct a commercial retail building on each property. The relevant provisions 

of each contract are identical. Vandervert hired subcontractors, including Brashear 

Electric, Inc. to work on both projects.

Vandervert’s contracts with the owners required it, for a period of one year after 

substantial completion, to promptly correct work not conforming to the contract 

requirements. The contracts required Vandervert to bear the cost of correcting its work. 

Vandervert’s contracts with Brashear required Brashear to assume all warranty 

obligations applicable to its work under Vandervert’s contracts with the owners. 

Brashear completed work on the Norcal project on June 28, 2017, and sent a 

final invoice to Vandervert on August 17, 2017. Brashear completed work on the Blue 
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

3

Bridge project on September 29, 2017, and sent a final invoice to Vandervert on 

October 26, 2017. The owners fully paid Vandervert. 

On January 8, 2018, a tenant of the Norcal building notified Vandervert that the 

roof was leaking. An initial inspection indicated that the leak was due to Brashear’s 

improper installation of the air conditioning unit. In accordance with the contractual 

warranty provision, Vandervert directed Brashear to send an electrician to fix the leak. 

On January 17, Jerry Peal, a Brashear electrician, applied caulking to temporarily 

fix the leak until a roofing contractor could make a permanent repair. Closer inspection 

revealed that Brashear was not at fault for the leak.

While Mr. Peal was on the Norcal property, Vandervert directed him to repair a 

loose connection in a light fixture at the Blue Bridge building. Mr. Peal fixed the loose 

connection.

On January 30, Brashear recorded a claim of lien against the Norcal property for

$12,830.81, the amount Vandervert owed it on that project. The next day, Brashear 

recorded a claim of lien against the Blue Bridge property for $36,278.50, the amount 

Vandervert owed it on that project. On February 2, 2018, Vandervert filed for 

receivership. 
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

4

In June 2018, Brashear commenced this action to foreclose its claims of liens 

against the two properties. Eventually, the parties filed cross motions for summary 

judgment. The trial court orally ruled in favor of the owners, determining that the 

warranty work did not extend the 90 day period for recording Brashear’s claims of liens. 

It later entered written orders. Brashear timely appealed.

ANALYSIS

PARTIES’ ARGUMENTS

Brashear contends the trial court misinterpreted RCW 60.04.091 and the 

surrounding statutory scheme. It argues the pertinent statutes are unambiguous and 

require a conclusion that its warranty work was “labor” that extended the time to record 

its claims of liens. Alternatively, if the pertinent statutes are ambiguous, it argues we 

must give them a liberal construction and reach a similar conclusion.

The owners argue the trial court properly strictly construed the pertinent statutes

when it ruled that the warranty work did not extend the time to record the claims of liens.

The owners cite Wells v. Scott, 75 Wn.2d 922, 454 P.2d 378 (1969), for the proposition 

that warranty work, especially minor warranty work, does not extend the time to record a 

claim of lien. 
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

5

Brashear responds that Wells was decided before enactment of chapter 

60.04 RCW. See LAWS OF 1991, ch. 281. It argues Wells no longer is controlling 

because RCW 60.04.900 requires provisions of the mechanics’ lien statutes “to be 

liberally construed to provide security for all parties intended to be protected by their 

provisions.”1

We first discuss whether our analysis is governed by rules of strict or liberal 

construction. We then construe the pertinent statutory scheme. 

A. STRICT OR LIBERAL CONSTRUCTION

Prior to 2011, the law was unclear as to what extent courts were required to strictly 

construe the mechanics’ lien statutes. The confusion was aptly summarized in 

Lumberman’s of Washington, Inc. v. Barnhardt, 89 Wn. App. 283, 286, 949 P.2d 382 

(1997): 

Although RCW 60.04.900 states that the lien statutes are to be liberally 

construed to provide security for all parties intended to be protected by their 

provisions, case law has established that mechanics’ and materialmen’s 

liens are creatures of statute, in derogation of common law, and therefore 

must be strictly construed to determine whether a lien attaches.

 

1 Brashear also relies on Kirk v. Rohan, 29 Wn.2d 432, 187 P.2d 607 (1947), to 

support its argument that warranty work extends the time to record a claim of lien. Kirk

is easily distinguishable on the basis that the contractor returned to perform warranty 

work and original contract work. Id. at 433-34.
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

6

In Williams v. Athletic Field, Inc., 172 Wn.2d 683, 261 P.3d 109 (2011), the 

Washington Supreme Court clarified when courts are to apply a strict or a liberal 

construction to chapter 60.04 RCW. The court reviewed the history of strict construction 

of the mechanics’ lien statutes. It noted that older cases applied the rule only when 

determining what people or services came within the protections of the mechanics’ lien 

statutes. Id. at 695. It then noted that a modern trend of cases applied strict construction 

more broadly. Id. at 696. Rejecting this modern trend, the court held:

[T]he appropriate way to view the competing canons of strict and liberal 

construction is found in our early cases. The strict construction rule, at its 

origin, was invoked to determine whether persons or services came within 

the statute’s protection. Expanding the rule of strict construction beyond 

this inquiry effectively nullifies RCW 60.04.900.

Id. 

Here, the question is whether warranty work, a type of service, comes within the 

protection of the mechanics’ lien statutes. We therefore strictly construe the pertinent

statutes to decide this question.

B. INTERPRETATION OF RCW 60.04.091

When interpreting a statute, an appellate court first considers the statute’s plain 

meaning. Williams, 172 Wn.2d at 693. “If the statute is ambiguous, we may consider 
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

7

aids to interpretation. A statute is ambiguous if it is susceptible to two or more 

reasonable interpretations.” Id. (citation omitted).

RCW 60.04.091 provides in relevant part:

Every person claiming a lien under RCW 60.04.021 shall file for recording 

. . . a notice of claim of lien not later than ninety days after the person has 

ceased to furnish labor, professional services, materials, or equipment . . . .

“Furnishing labor, professional services, materials, or equipment” is defined to 

include “any labor . . . for the improvement of real property.” RCW 60.04.011(4)

(emphasis added). “Improvement” includes “[c]onstructing, altering, repairing, 

remodeling, demolishing, clearing, grading, or filling in, of, to, or upon” real property. 

RCW 60.04.011(5)(a) (emphasis added).

Brashear’s warranty work certainly involved labor. The question is whether its 

warranty work involved labor “repairing” real property. More directly, does “repairing” 

extend to correcting one’s own nonconforming work? 

To discern the meaning of a word undefined by statute, we often turn to a 

dictionary definition. State v. A.M.R., 147 Wn.2d 91, 94, 51 P.3d 790 (2002). “Repair” 

means “to restore by replacing a part or putting together what is torn or broken.” 

WEBSTER’S THIRD NEW INTERNATIONAL DICTIONARY 1923 (1993). “Restore” strongly 

suggests that the broken thing once worked properly. “Nonconforming work” suggests 
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

8

the opposite. A strict construction of “repairing” supports a conclusion that it does not 

encompass correcting one’s own nonconforming work.

Another rule of construction leads us to the same conclusion. The principle of 

noscitur a sociis provides:

“[A] single word in a statute should not be read in isolation. Rather, the 

meaning of a word may be indicated or controlled by reference to associated

words. In applying this principle to determine the meaning of a word in a 

series, a court should ‘take into consideration the meaning naturally 

attaching to them from the context, and . . . adopt the sense of the words 

which best harmonizes with the context.’”

State v. Barnes, 189 Wn.2d 492, 503, 403 P.3d 72 (2017) (second alteration in original) 

(Wiggins, J., concurring) (quoting State v. Gonzales Flores, 164 Wn.2d 1, 12, 186 P.3d 

1038 (2008)).

The series of words—“[c]onstructing, altering, repairing, remodeling, demolishing,

clearing, grading, or filling in”—can be harmonized by recognizing that contractors are 

hired and paid to do each of these things. With respect to repairing, contractors are hired 

and paid to restore something that is broken. They are not hired and paid to correct their 

own nonconforming work. Rather, their own work is warrantied, and they are 

contractually obligated to correct it at no cost to the owner. 
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

9

An additional rule of construction leads us to the same result. A statute is 

construed to effect its legislative purpose, while avoiding unlikely, absurd, or strained 

consequences. Sanders v. State, 166 Wn.2d 164, 172, 207 P.3d 1245 (2009). A lien is 

intended to secure payment for money owed. A contractor is not paid to correct its own 

nonconforming work. Warranty work, therefore, is not lienable. It is unlikely that the 

legislature intended for nonlienable warranty work to extend the time to record a claim of 

lien. 

The result here is consistent with the 1969 case of Wells, 75 Wn.2d 922. There, 

Wells performed electrical work on two buildings owned by Scott. Id. Wells completed 

work on September 1, 1965. Id. at 925. Wells had guaranteed the work for one year after 

completion. Id. On May 6, 1966, Scott instructed Wells to correct two defective circuit 

breakers in one building. Id. In June, Scott then recorded a claim of lien. Id.
No. 37379-7-III

Brashear Elec., Inc. v. Norcal Props., LLC

10

The Wells court disposed of the electrician’s argument in a single paragraph, 

without citation to any previous case or statute:

2

The trial court correctly held that a labor and materialman’s lien is a 

creature of statute in derogation of common law, and that its statutory terms 

must be strictly construed. It held that since construction of the buildings 

was completed on September 1, 1965, the 90-day filing period for a claim 

of lien commenced to run at that time; that since the claim was not filed 

until approximately 280 days thereafter, it was of no force and effect. We 

concur. The 1-year guarantee did not extend the statutory time within 

which the claim of lien could properly be recorded.

 

2 The pertinent statutes then in effect did not contain a definition of 

“improvement,” but were otherwise substantially the same as those we construe today. 

They provided: 

[RCW] 60.04.060 Claim—Contents—Form—Filing—Joinder. 

No lien created by this chapter shall exist, and no action to enforce the same 

shall be maintained, unless within ninety days from the date of the cessation 

of the performance of such labor, the furnishing of such materials, or the 

supplying of such equipment, a claim for such lien shall be [recorded] . . . .

See LAWS OF 1959, ch. 279, § 5.

[RCW] 60.04.010 Lien authorized—Bond by railroad company.

Every person performing labor upon, furnishing material, or renting, leasing 

or otherwise supplying equipment, to be used in the construction, alteration 

or repair of any . . . building . . . or any other structure . . . has a lien upon 

the same for the labor performed, material furnished, or equipment supplied 

. . . .

See LAWS OF 1959, ch. 279, § 1.

In addition, the following note was contained below the text of RCW 60.04.010:

Construction: “The provisions of law relating to liens created by 

this act, and all proceedings thereunder, shall be liberally construed with a 

view to effect their objects.” [1893 c 24 § 18.]
i 

No. 37379-7-III j Brashear Elec., Inc. v. M real Props., LLC 

Id. 

I 

Our analysis provires a statutory framework consistent with the conclusion in 

i 

Wells: Warranty work dob not extend the time to record a claim of lien. 

C. ATTORNEYjFEES AND COSTS 

I 

The owners reque~t an award of attorney fees and costs and cite 

I 

RCW 60.04.181(3) in su~port of their request. RCW 60.04.181(3) provides in relevant 

part: 

I 

i 

The court may all~w the prevailing party in the [lien foreclosure] action, 

whether plaintiff o defendant, as part of the costs of the action, the moneys 

paid for recording he claim of lien, costs of title report, bond costs, and 

attorneys' fees an~ necessary expenses incurred by the attorney in the 

superior court, co rt of appeals, supreme court, or arbitration, as the court 

or arbitrator deem reasonable. 

Provided the own~rs comply with RAP 18.l(d), we grant them an award of ! 

reasonable attorney fees ~d necessary expenses incurred on appeal. That award will be 

I 

determined by our comm·ssioner. RAP 18.l(f). 

Affirmed. 

WE CONCUR: j 

~. ~- . Pennell, C.J. Siddoway, J. 

11