Federal Register / Vol. 86, No. 110 / Thursday, June 10, 2021 / Notices 30937 

Regulation Part 36 Construction 

Contract Requirements.’’ Upon approval 

of this consolidated information 

collection, OMB Control Nos. 9000– 

0058 and 9000–0060 will be 

discontinued. The burden requirements 

previously approved under the 

discontinued numbers will be covered 

under OMB Control No. 9000–0062. 

This clearance covers the information 

that contractors must submit to comply 

with the following FAR part 36 

requirements: 

• FAR 52.236–5, Material and 

Workmanship. This clause requires the 

contractor to obtain contracting officer 

approval of the machinery, equipment, 

material, or articles to be incorporated 

into the work. The contractor’s request 

must include: The manufacturer’s name, 

the model number, and other 

information concerning the 

performance, capacity, nature, and 

rating of the machinery and mechanical 

and other equipment; and full 

information concerning the material or 

articles. When directed by the 

contracting officer, the contractor must 

submit sufficient information on and, in 

some cases, samples of the items 

requiring approval. The contracting 

officer uses this information to 

determine whether the machinery, 

equipment, material, or articles meet the 

standards of quality specified in the 

contract. A contracting officer may 

reject work if the contractor installs 

machinery, equipment, material, or 

articles in the work without obtaining 

the contracting officer’s approval. 

• FAR 52.236–13, Accident 

Prevention, Alternate I. This alternate to 

the basic clause requires the contractor 

to submit a written proposed plan to 

provide and maintain work 

environments and procedures that will 

safeguard the public and Government 

personnel, property, materials, supplies, 

and equipment exposed to contractor 

operations and activities; avoid 

interruptions of Government operations 

and delays in project completion dates; 

and control costs in the performance of 

this contract. The plan must include an 

analysis of the significant hazards to 

life, limb, and property inherent in 

contract work performance and a plan 

for controlling these hazards. The 

contracting officer and technical 

representatives analyze the Accident 

Prevention Plan to determine if the 

proposed plan will satisfy the safety 

requirements identified in the contract, 

to include certain provisions of the 

Occupational Safety and Health Act and 

applicable standards issued by the 

Secretary of Labor at 29 CFR part 1926 

and 29 CFR part 1910. 

• FAR 52.236–15, Schedules for 

Construction Contracts. This clause 

requires the contractor to prepare and 

submit to the contracting officer for 

approval three copies of a practicable 

schedule showing the order in which 

the contractor proposes to perform the 

work, and the dates on which the 

contractor contemplates starting and 

completing the several salient features 

of the work (including acquiring 

materials, plant, and equipment). The 

contracting officer uses this information 

to monitor progress under a Federal 

construction contract when other 

management approaches for ensuring 

adequate progress are not used. 

C. Annual Burden 

Respondents: 4,412. 

Total Annual Responses: 15,352. 

Total Burden Hours: 12,034. 

Obtaining Copies: Requesters may 

obtain a copy of the information 

collection documents from the GSA 

Regulatory Secretariat Division by 

calling 202–501–4755 or emailing 

GSARegSec@gsa.gov. Please cite OMB 

Control No. 9000–0062, Certain Federal 

Acquisition Regulation Part 36 

Construction Contracts Requirements. 

Janet Fry, 

Director, Federal Acquisition Policy Division, 

Office of Governmentwide Acquisition Policy, 

Office of Acquisition Policy, Office of 

Governmentwide Policy. 

[FR Doc. 2021–12135 Filed 6–9–21; 8:45 am] 

BILLING CODE 6820–EP–P 

DEPARTMENT OF HEALTH AND 

HUMAN SERVICES 

Centers for Disease Control and 

Prevention 

[60Day–21–0314; Docket No. CDC–2021– 

0056] 

Proposed Data Collections Submitted 

for Public Comment and 

Recommendations 

AGENCY: Centers for Disease Control and 

Prevention (CDC), Department of Health 

and Human Services (HHS). 

ACTION: Notice with comment period. 

SUMMARY: The Centers for Disease 

Control and Prevention (CDC), as part of 

its continuing effort to reduce public 

burden and maximize the utility of 

government information, invites the 

general public and other Federal 

agencies the opportunity to comment on 

a proposed and/or continuing 

information collection, as required by 

the Paperwork Reduction Act of 1995. 

This notice invites comment on a 

proposed information collection project 

titled The National Survey of Family 

Growth (NSFG), designed to provide 

nationally representative, scientifically 

credible data on factors related to birth 

and pregnancy rates, family formation 

and dissolution patterns, and 

reproductive health. 

DATES: CDC must receive written 

comments on or before August 9, 2021. 

ADDRESSES: You may submit comments, 

identified by Docket No. CDC–2021– 

0056 by any of the following methods: 

• Federal eRulemaking Portal: 

Regulations.gov. Follow the instructions 

for submitting comments. 

• Mail: Jeffrey M. Zirger, Information 

Collection Review Office, Centers for 

Disease Control and Prevention, 1600 

Clifton Road NE, MS–D74, Atlanta, 

Georgia 30329. 

Instructions: All submissions received 

must include the agency name and 

Docket Number. CDC will post, without 

change, all relevant comments to 

Regulations.gov. 

Please note: Submit all Comments 

through the Federal eRulemaking portal 

(regulations.gov) or by U.S. mail to the 

address listed above. 

FOR FURTHER INFORMATION CONTACT: To 

request more information on the 

proposed project or to obtain a copy of 

the information collection plan and 

instruments, contact Jeffrey M. Zirger, 

Information Collection Review Office, 

Centers for Disease Control and 

Prevention, 1600 Clifton Road NE, MS– 

D74, Atlanta, Georgia 30329; phone: 

404–639–7118; Email: omb@cdc.gov. 

SUPPLEMENTARY INFORMATION: Under the 

Paperwork Reduction Act of 1995 (PRA) 

(44 U.S.C. 3501–3520), Federal agencies 

must obtain approval from the Office of 

Management and Budget (OMB) for each 

collection of information they conduct 

or sponsor. In addition, the PRA also 

requires Federal agencies to provide a 

60-day notice in the Federal Register 

concerning each proposed collection of 

information, including each new 

proposed collection, each proposed 

extension of existing collection of 

information, and each reinstatement of 

previously approved information 

collection before submitting the 

collection to the OMB for approval. To 

comply with this requirement, we are 

publishing this notice of a proposed 

data collection as described below. 

The OMB is particularly interested in 

comments that will help: 

1. Evaluate whether the proposed 

collection of information is necessary 

for the proper performance of the 

functions of the agency, including 

whether the information will have 

practical utility; 


khammond on DSKJM1Z7X2PROD with NOTICES
30938 Federal Register / Vol. 86, No. 110 / Thursday, June 10, 2021 / Notices 

2. Evaluate the accuracy of the 

agency’s estimate of the burden of the 

proposed collection of information, 

including the validity of the 

methodology and assumptions used; 

3. Enhance the quality, utility, and 

clarity of the information to be 

collected; 

4. Minimize the burden of the 

collection of information on those who 

are to respond, including through the 

use of appropriate automated, 

electronic, mechanical, or other 

technological collection techniques or 

other forms of information technology, 

e.g., permitting electronic submissions 

of responses; and 

5. Assess information collection costs. 

Proposed Project 

The National Survey of Family 

Growth (NSFG)—(OMB Control No. 

0920–0314, Exp. 06/30/2021)— 

Reinstatement—National Center for 

Health Statistics (NCHS), Centers for 

Disease Control and Prevention (CDC). 

Background and Brief Description 

Section 306 of the Public Health 

Service (PHS) Act (42 U.S.C. 242k), as 

amended, authorizes that the Secretary 

of Health and Human Services (DHHS), 

acting through NCHS, shall collect 

statistics on ‘‘family formation, growth, 

and dissolution,’’ as well as 

‘‘determinants of health’’ and 

‘‘utilization of health care’’ in the 

United States. This clearance request 

includes the data collection in 2022– 

2024 for the continuous National Survey 

of Family Growth (NSFG). 

The NSFG was conducted 

periodically between 1973 and 2002, 

continuously in 2006–2010, and after a 

break of 15 months, continuously in 

2011–2019, by the National Center for 

Health Statistics (NCHS/CDC). Each 

year, about 13,500 households will be 

screened, with about 5,000 participants 

interviewed annually. Participation in 

the NSFG is completely voluntary and 

confidential. Interviews are expected to 

average 50 minutes for males and 75 

minutes for females. The response rate 

during the 2011–2019 data collection 

period ranged from 64.5% to 74.0%, 

and the cumulative response rate for 

this eight-year fieldwork period was 

67.7%. 

The NSFG program produces 

descriptive statistics which document 

factors associated with birth and 

pregnancy rates, including 

contraception, infertility, marriage, 

cohabitation, and sexual activity, in the 

US household population 15–49 years 

(15–44 prior to 2015), as well as 

behaviors that affect the risk of HIV and 

other sexually transmitted diseases 

(STD). The survey also disseminates 

statistics on the medical care associated 

with contraception, infertility, 

pregnancy, and related health 

conditions. 

NSFG data users include the DHHS 

programs that fund the survey, 

including CDC/NCHS and 11 others 

within the Department of Health and 

Human Services: 

• Eunice Kennedy Shriver National 

Institute for Child Health and Human 

Development (NIH/NICHD) 

• Office of Population Affairs (OPA) 

• Children’s Bureau in the 

Administration for Children and 

Families (ACF/CB) 

• Office of Planning, Research, and 

Evaluation (ACF/CB) 

• Office on Women’s Health (OASH/ 

OWH) 

• CDC’s Division of HIV/AIDS 

Prevention (CDC/NCHHSTP/DHAP) 

• CDC’s Division of STD Prevention 

(CDC/NCHHSTP/DSTDP) 

• CDC’s Division of Adolescent and 

School Health (CDC/NCHHSTP/ 

DASH) 

• CDC’s Division of Reproductive 

Health (CDC/NCCDPHP/DRH) 

• CDC’s Division of Cancer Prevention 

and Control (CDC/NCCDPHP/DCPC) 

• CDC’s Division of Violence 

Prevention (CDC/NCIPC/DVP) 

The NSFG is also used by state and 

local governments (primarily for 

benchmarking to national data); private 

research and action organizations 

focused on men’s and women’s health, 

child well-being, and marriage and the 

family; academic researchers in the 

social and public health sciences; 

journalists, and many others. 

This submission requests approval to 

reinstate NSFG data collection for three 

years. The reinstatement request 

includes the conduction of several 

methodological studies designed to 

improve the efficiency and validity of 

NSFG data collection for the purposes 

described above. The total estimated 

annualized time burden to respondents 

is 6,119 hours. There is no cost to 

respondents other than their time. 

ESTIMATED ANNUALIZED BURDEN HOURS

Respondents Form Number of 

responses 

Responses 

per 

respondent 

Average 

burden/ 

response 

(in hours) 

Total burden 

hours 

Household member ........................................... Screener Interview ............................................ 13,500 1 3/60 675 

Household Female 15–49 years of age ............ Female Interview ............................................... 2,750 1 75/60 3,438 

Household Male 15–49 years of age ................ Male Interview ................................................... 2,250 1 50/60 1,875 

Household member ........................................... Screener Verification ......................................... 1,500 1 2/60 50 

Household Individual 15–49 years of age ......... Main Interview Verification ................................ 500 1 5/60 42 

Household Female 15–49 years of age ............ Respondent debriefing questions about calendar.150 1 3/60 8 

Household member ........................................... Phase 4 nonresponse follow-up questions ....... 375 1 5/60 31 

Total ............................................................ ........................................................................... ........................ ........................ ........................ 6,119 

Jeffrey M. Zirger, 

Lead, Information Collection Review Office, 

Office of Scientific Integrity, Office of Science, 

Centers for Disease Control and Prevention. 

[FR Doc. 2021–12210 Filed 6–9–21; 8:45 am] 

BILLING CODE 4163–18–P 


khammond on DSKJM1Z7X2PROD with NOTICES