17-3468(L)

MPM Silicones, LLC v. Union Carbide Corp.

UNITED STATES COURT OF APPEALS

FOR THE SECOND CIRCUIT

August Term, 2019

(Argued: May 8, 2019 Decided: July 23, 2020)

Docket No. 17-3468(L), 17-3669(XAP)

_____________________________________

MPM Silicones, LLC,

Plaintiff-Counter-Defendant-Appellant-Cross-Appellee,

v.

Union Carbide Corporation,

Defendant-Counter-Claimant-Appellee-Cross-Appellant.

_____________________________________

Before:

DENNIS JACOBS, PIERRE N. LEVAL, Circuit Judges.1

In cross-appeals from the judgment of the United States District Court 

for the Northern District of New York (Brenda K. Sannes, J.), Plaintiff MPM 

Silicones, LLC (“MPM”) appeals the grant of partial summary judgment

dismissing its claims for recovery of “remedial action” costs under the 

Comprehensive Environmental Response, Compensation, and Liability Act 

(“CERCLA”) as barred by the statute of limitations in 42 U.S.C. § 9613(g)(2). 

Defendant Union Carbide Corporation (“UCC”) cross-appeals from the district 

court’s holding after a bench trial that UCC is liable to MPM for 95% of the cost 

of future “removal action.” Held, the district court’s conclusion that MPM’s 

1 Judge Christopher F. Droney, who was originally part of the panel assigned to hear this case, 

retired from the Court effective January 1, 2020. The remaining two members of the panel are

in agreement regarding this opinion and order. See 28 U.S.C. § 46(d); 2d Cir. IOP E(b).
2

claims for recovery of remedial action costs were time-barred relied on an 

incorrect interpretation of our decision in New York State Electric and Gas Corp. 

v. FirstEnergy Corp., 766 F.3d 212 (2d Cir. 2014); the district court made no error 

in adjudicating the allocation of future removal action costs, or in allocating 

95% against UCC. AFFIRMED in part; VACATED and REMANDED in part.

JONATHAN M. ETTINGER, Foley Hoag 

LLP, Boston, MA, (Jeremy W. 

Meisinger, Foley Hoag LLP, Boston, 

MA, Peter A. Sullivan, Foley Hoag LLP, 

New York, NY, on the brief) for PlaintiffCounter-Defendant-Appellant-CrossAppellee MPM Silicones, LLC.

HAROLD L. SEGALL, Beveridge & 

Diamond, P.C., Washington, DC, (Karl 

S. Bourdeau, Benjamin E. Apple, 

Beveridge & Diamond, P.C., 

Washington, DC, Megan R. Brillault, 

Beveridge & Diamond, P.C., New York, 

NY, on the brief) for Defendant-CounterClaimant-Appellee-Cross-Appellant Union 

Carbide Corporation.

TABLE OF CONTENTS

A. BACKGROUND............................................................................................................. 6

I. UCC’S USE OF PCBS AT THE SITE ................................................................................ 6

I. SUBSEQUENT OWNERSHIP OF THE SITE ...................................................................... 17

II. MPM DISCOVERS BURIED PCBS................................................................................. 21

III. PROCEDURAL HISTORY .............................................................................................. 24

IV. THE DISTRICT COURT’S JULY 2016 ORDER.................................................................. 27

V. THE DISTRICT COURT’S SEPTEMBER 2017 ORDER....................................................... 30
3

B. DISCUSSION................................................................................................................ 33

I. STATUTE OF LIMITATIONS .......................................................................................... 33

a. UCC’s construction of the earthen cap and the diversion ditch in 1992 were 

remedial........................................................................................................................... 44

b. NYSEG’s single-remediation principle was not intended to govern all 

circumstances ................................................................................................................. 47

II. FUTURE REMOVAL COSTS .......................................................................................... 67

a. Constitutional ripeness........................................................................................... 69

b. Prudential ripeness................................................................................................. 71

c. Future removal cost allocation ............................................................................... 77

C. CONCLUSION............................................................................................................. 81

JACOBS and LEVAL, Circuit Judges:

These are cross-appeals by Plaintiff MPM Silicones, LLC (“MPM”) and 

Defendant Union Carbide Corporation (“UCC”) from different aspects of the 

judgment of the United States District Court for the Northern District of New 

York (Brenda J. Sannes, J.). Plaintiff MPM owns and operates the Sistersville 

site (“Sistersville” or the “Site”), a manufacturing facility in Friendly, West 

Virginia. The Site was previously owned and operated by Defendant UCC for 

many decades. 

In the course of UCC’s manufacturing operations at the Site in the 1960s 

and 1970s, UCC generated substantial amounts of toxic polychlorinated 
4

biphenyl (“PCB”) waste and buried that waste in various areas of the site. After 

MPM acquired the Site, it discovered some of this buried PCB waste and 

undertook a program of clean-up activity in response. MPM brought this suit 

against UCC under the Comprehensive Environmental Response, 

Compensation, and Liability Act (“CERCLA”) to recover from UCC the costs it 

had incurred (and would incur) in cleaning up UCC’s PCB contamination. 

As explained below, with respect to the timeliness of CERCLA suits to 

recover such response costs, the governing statute distinguishes between what 

it identifies as “removal” action, 42 U.S.C. § 9601(23), which is generally urgent 

action taken to deal, at least temporarily, with an immediate health hazard, and 

“remedial action,” id. § 9601(24), which is less urgent action whose objective is 

to eventually achieve a comprehensive, permanent remedy. See New York State 

Elec. and Gas Corp. v. FirstEnergy Corp., 766 F.3d 212, 230–31 (2d Cir. 2014). The 

timeliness of cost recovery suits is governed by very different standards, 

depending on whether the costs were incurred in “remedial action” or in 

“removal action.” 42 U.S.C. § 9613(g)(2). In this opinion, we use the terms 

“removal” and “remediation” (or “remedial”) not in their colloquial senses, but 
5

to refer respectively to the statutory terms “removal action” and “remedial 

action.” 

With respect to MPM’s claims to recover remediation costs, the district 

court granted summary judgment to UCC on the grounds that, under 42 U.S.C. 

§ 9613(g)(2), the suit was time-barred. MPM Silicones, LLC v. Union Carbide 

Corp., No. 1:11-cv-1542, 2016 WL 3962630, at *14–19 (N.D.N.Y. July 7, 2016) 

(“MPM I”). On the other hand, as for removal costs, the court held by summary 

judgment that UCC was liable to MPM, id. at *31, but that MPM was obligated 

to cover a part of those costs, reserving the precise allocation for trial, MPM 

Silicones, LLC v. Union Carbide Corp., No. 1:11-cv-01542, Dkt. No. 165 (N.D.N.Y., 

Dec. 8, 2016) (“MPM II”). After a bench trial, the court allocated 95% of future 

removal costs to UCC with 5% to be borne by MPM. MPM Silicones, LLC v. 

Union Carbide Corp., No. 1:11-cv-1542, 2017 WL 6408611, at *15–21 (N.D.N.Y. 

Sept. 22, 2017) (“MPM III”). MPM and UCC each challenge aspects of those 

rulings on this appeal. 

We hold that the district court relied on invalid reasoning in concluding 

that MPM’s claim for recovery of the costs of its remediation efforts is timebarred by 42 U.S.C. § 9613(g)(2). We therefore vacate that ruling and remand 
6

for further consideration of the timeliness of MPM’s suit to recover its 

remediation costs. As to costs of future removal, we hold that the district court 

correctly ruled that the issue of cost allocation was ripe for review and did not 

abuse its discretion in allocating responsibility for 95% to UCC. 

A. BACKGROUND

i. UCC’s use of PCBs at the Site

The Site consists of 1,300 acres of land in a rural area bordering the Ohio 

River. The site was undeveloped farmland until UCC acquired it and 

constructed manufacturing facilities. UCC operated those facilities to 

manufacture a variety of chemical products from approximately 1955 to April 

1993. Today, the site is still used for chemical manufacturing and contains 

several facilities for the storage, treatment, and disposal of manufacturing 

waste — known as “Solid Waste Management Units” — including a 

wastewater treatment unit, an active hazardous waste landfill, and two inactive

waste-disposal areas. These are known as the North Inactive Site and the South 

Inactive Site. 

During its operation of the Site, UCC used hundreds of thousands of 

pounds of polychlorinated biphenyls (“PCBs”) in its manufacturing processes. 
7

Those processes created substantial PCB-laden chemical wastes. UCC disposed 

of that waste by burning it, or by depositing it into neutralization tanks or lime 

pits at the Site. After the lime pits filled with sludge, UCC drained them and 

dug them out, and used the PCB-laden sludge to backfill other areas of the Site. 

Some of the PCB-laden waste was deposited in the North Inactive Site, a 5.5 

acre landfill located uphill and northwest of the Site’s waste water treatment 

facility and a creek that runs through the Site, known as Sugar Camp Run. See 

Dist. Ct. Dkt. No. 77-1 at 48 (map of the Site); see also Dist. Ct. Dkt. No. 80-17 at 

82–85 (ENVIRON Map of Site). The precise locations of all the backfill areas are 

unknown.

Figure 1: Partial Map of the Site (Dist. Ct. Dkt. No. 77-1 at 48)
8

Figure 2: Partial Map of the Site (Dist. Ct. Dkt. No. 80-17 at 82)

UCC used PCBs at Sistersville until 1972, when environmental concerns 

regarding PCB toxicity began to emerge.2 In 1979, after soil sample analysis 

reported the presence of PCBs in Sugar Camp Run, UCC began to investigate 

its past waste disposal practices. Clem Schubert, a UCC employee, was tasked 

with that investigation. Schubert conducted interviews with individuals 

knowledgeable about UCC’s historical waste disposal practices and learned 

about UCC’s practice of disposing of PCB-laden wastes in lime ponds and 

2 PCBs are now designated as a “hazardous constituent” under the Resource Conservation 

and Recovery Act (“RCRA”). 40 C.F.R. Pt. 261, App. VIII. 
9

neutralization tanks, and backfilling areas of the Site with sludge from the lime 

ponds. Schubert identified several areas in the North Inactive Site and several 

locations south of the wastewater treatment plant where he believed UCC had 

dumped PCB wastes and further determined that UCC had shifted around 

previously buried waste during several construction projects. Schubert 

summarized his findings in a January 1980 memorandum, in which he stated 

that “it is reasonable to conclude that in the area of the Sistersville Plant site 

there are buried . . . heavies with up to 250,000 pounds of PCB[s].” Dist. Ct. Dkt. 

238 at 71. That memorandum was circulated to UCC employees, including 

UCC’s Plant Manager. 

UCC conducted several rounds of testing for various contaminants 

(including PCBs) at the Site between 1979 and 1981. While some tests showed 

low levels of PCBs in groundwater, the results overall were inconsistent and 

revealed only small amounts of PCBs. 3 In 1984, a UCC memorandum 

3 For example, a June 1979 potable water test revealed 10 parts per billion (“ppb”) of PCBs in 

the water at the Site. UCC retested the water in the following month, found no PCBs, and 

concluded that the presence of PCBs in the June 1979 sample was a result of laboratory 

contamination. One test in March 1980 detected PCBs in a well near the North Inactive Site, 

but further tests in the same location performed a year later did not detect PCBs. 
10

regarding contamination at the North Inactive Site recognized that “[a]lthough 

no definitive evidence can be found, it is possible that up to 250,000 pounds of 

PCB[s] are buried at this site . . . However, wells at this site when last monitored 

in 1981 showed no significant leaching or contamination and no PCB[s] were 

found.” Dist. Ct. Dkt. 78–10 at 1. A 1992 memorandum summarizing all prior 

UCC investigations into PCBs at the Site — including Schubert’s 1980 

memorandum — concluded that “it is not possible to state unequivocally that 

PCB[s] were not placed in the north inactive site” but that “[i]nformation 

suggesting disposal is purely speculative” because “[m]onitoring data to date 

do not substantiate the speculation.” App’x 382–83. At various times during 

the 1980s and 1990s, UCC employees speculated that the low levels of PCBs 

detected by UCC’s site monitoring tests were the result of spillage from PCBcontaining electrical equipment that UCC had used at the site. 

In 1981, as required by the recently enacted Resource Conservation and 

Recovery Act (“RCRA”), see 42 U.S.C. §§ 6901–6992k, UCC submitted an

application to the Environmental Protection Agency (“EPA”) for a permit to 

treat, store, or destroy hazardous waste. RCRA established a framework to 

“ensure the proper treatment, storage, and disposal of [hazardous] waste.” 
11

Prisco v. A&D Carting Corp., 168 F.3d 593, 608 (2d Cir. 1999) (citation omitted). 

It requires the owner or operator of any “facility that treats, stores, or disposes 

of hazardous wastes” to “seek[] and obtain[] a permit from the [EPA].” Owen 

Elec. Steel Co. of S.C., Inc. v. Browner, 37 F.3d 146, 147 (4th Cir. 1994); see also 42 

U.S.C. § 6925(a). The statute requires the EPA to evaluate the environmental 

risks of any such facility and to issue permits requiring the owner or operator 

of a facility to undertake “corrective action for all releases of hazardous waste 

. . . from any solid waste management unit.” 42 U.S.C. § 6924(u). 

UCC’s permit application required its disclosure of any “hazardous 

substances” that had been “stored, treated, or disposed of” at the Site. See 

Hazardous Substances: Notification of Treatment, Storage and Disposal 

Facilities, 46 Fed. Reg. 22144, 22145 (Apr. 15, 1981); see also 42 U.S.C. § 9603(c) 

(requiring disclosure of certain facility owners of the “stor[age], treat[ment], or 

dispo[sal]” of any “hazardous substances”). 4 While UCC indicated on the 

4 EPA regulations at the time did not require UCC to disclose any information regarding 

PCBs. This was because PCBs were then “not included within the RCRA definitions of 

hazardous waste” as they were regulated under a different statutory framework. See 

Hazardous Substances: Notification of Treatment, Storage and Disposal Facilities, 46 Fed. 

Reg. 22144, 22145 (Apr. 15, 1981) (making disclosure of PCB contamination voluntary).
12

application that it was aware of several types of hazardous waste at the Site, it 

did not disclose its prior use of PCBs, leaving a check box for “PCBs” 

unchecked.5

In its written correspondence with the EPA regarding its RCRA permit 

for Sistersville, UCC made no mention of its prior use of PCBs or its dumping 

of PCB-laden waste. In response to the EPA’s 1985 request for information 

about all solid waste management units at the Site that had “the potential to 

release hazardous wastes or hazardous constituents to the environment,” Sp. 

App’x 87, UCC disclosed general information about some potential 

contaminants at the North and South Inactive Sites but did not mention PCBs.6

5 Fred Dailey, a long-time UCC employee, indicated in a 1981 memorandum to other UCC 

employees that he had advised the EPA representatives that UCC had manufactured 

chemicals that could have produced PCB waste from 1956 to 1962, but that UCC’s “experts 

[felt] that [UCC] did not make any PCBs.” Sp. App’x 86. Moreover, Dailey indicated that he 

told the EPA representatives that UCC used electrical equipment at Sistersville that contained 

PCBs. 

In 1987, Dailey wrote to UCC’s legal counsel Carol Dudnick, asking Dudnick whether UCC 

should revise one of its EPA submissions — the “Notification of Hazardous Waste” form —

to disclose the possibility that UCC had dumped PCB-laden waste at the inactive disposal 

sites at Sistersville. Dudnick advised Dailey that it was unnecessary to add PCBs to the form 

because the information on PCB contamination was “speculative at best,” because there was 

no documentation that anyone at UCC had actual knowledge of PCB disposal at the site, and 

because UCC’s monitoring and testing had not detected any PCBs. Id. at 89.

6 UCC’s response to the EPA recounted a list of waste components that was roughly identical 

to the list of waste contaminants Schubert had listed in his 1980 memo, but conspicuously 
13

In response to the EPA’s 1986 further request for information regarding the 

solid waste management units, UCC disclosed the results of its site testing, 

which showed that, if any PCBs were present in the tested samples, that 

presence was below detection limits. UCC did not communicate its history of 

PCB use and disposal at Sistersville. 

EPA representatives visited the Site on May 15, 1986, and while the 

parties dispute what happened during that visit, Fred Dailey, a UCC employee,

wrote a memorandum in 1987 — one year after the visit — stating that, during 

the visit, he informed the EPA orally that “it was speculated that as much as 

500,000 lbs of contaminated PCB heat fluid was generated during the plant’s 

previous activities,” that “its disposition was never determined,” and that “it 

could have been placed in an inactive site.” Sp. App’x 88. Dailey’s memo then 

stated that he told the EPA representatives that UCC had conducted 

groundwater testing and examination of the inactive sites at Sistersville, and 

that “[a]ll the results of the tests and analyses conducted showed no PCBs.” Id.

deleted from that list Schubert’s conclusion that the site contained “heavies with up to 250,000 

pounds of PCB[s].” Sp. App’x 87–88.
14

According to Dailey’s 1987 memorandum, the EPA representatives did not 

further inquire about PCBs during the meeting. 

In 1988, the West Virginia Division of Natural Resources (“WVDNR”) —

which was authorized by the EPA to administer certain provisions of RCRA —

issued UCC a permit covering Sistersville’s active hazardous waste 

management units. That permit included a “Remedial Action Plan” requiring 

UCC to treat the groundwater near a copper sludge removal pond at 

Sistersville. In 1991, UCC installed a recovery well, which was part of a larger 

project to close the sludge pond. 

Also in 1988, the EPA issued a RCRA permit to UCC for Sistersville. The 

EPA determined that eight of the solid waste management units at the Site —

including the North Inactive Site and the wastewater treatment system —

required further investigation and required UCC to submit a workplan to 

remediate hazardous waste issues at each unit. The EPA’s RCRA permit did 

not mention PCBs. UCC submitted a workplan for the North Inactive Site in 

1992, which concluded that the area was a source of contamination and 

recommended construction of an earthen cap to reduce surface water, 

sediment, and groundwater contamination. UCC’s 1992 submission to the EPA 
15

did not mention PCBs because of what UCC later referred to as “an inadvertent 

failure to perform PCB analysis.” Dist. Ct. Dkt. 89-1 at 25 ¶ 62. The EPA 

accepted UCC’s proposal, and UCC undertook construction of the earthen cap 

in the summer and fall of 1992. 7 The same year, UCC also constructed a 

diversion ditch to intercept surface water from the hillside and divert it away 

from the disposal area. In 1993, UCC wrote a letter to the EPA advising that it 

inadvertently failed to disclose PCBs in its 1992 report and disclosing sampling 

results from Sugar Camp Run showing low levels of PCBs. The EPA did not 

require any further action in response to this additional disclosure.

None of the corrective actions undertaken by UCC were designed to 

investigate or address the possibility that large amounts of PCB-laden wastes 

were buried at Sistersville. Instead, the construction of the earthen cap and the 

diversion ditch for the North Inactive Site were designed to address the 

presence of other contaminants in groundwater and soil in various parts of the 

north end of the Site — contaminants UCC believed to have originated at the 

7 UCC’s corrective actions taken during 1992 also included an effort to stabilize the banks of 

Sugar Camp Run and to build new fencing to prevent erosion of the creek. 
16

North Inactive Site.8 As more recent events make clear, a full investigation into 

UCC’s historical PCB waste dumping would have required a comprehensive 

sampling program in the vicinity of the North Inactive Site and other potential 

dumping sites and in Sugar Camp Run. UCC did not conduct such a study, nor 

did the EPA require it to.9 Documents produced in the 1980s and 1990s show 

that UCC’s position was that any PCBs found during site monitoring were 

likely the result of spillage from its PCB-containing electrical equipment. UCC 

removed all PCB-containing electrical equipment from the Site by mid-1991, 

and subsequently declared that the Site had attained “PCB ‘free’ status.” Sp. 

App’x 90.

8 The 1992 RCRA Facility Investigation Report for the North Inactive Site lists various 

chemicals in groundwater and sediment samples that were believed to have originated in the 

North Inactive Site, including zinc and copper. 

9 The parties disagree as to whether the EPA would have required UCC to undertake 

corrective action to remediate the PCB contamination at the Site had UCC been more 

forthcoming about its historical PCB use and disposal. UCC argues that it disclosed its past 

practices, pointing to Dailey’s notes regarding the 1986 site visit. MPM argues that Dailey’s 

notes are “self-serving” and that UCC intentionally concealed its past practices from 

regulators (and, by extension, from subsequent owners) by failing to disclose them in its 

written correspondence with the EPA, and assumes that the EPA would have required 

corrective action had it known the full history of PCB use at the site. Notably, however, after 

MPM discovered PCB-contaminated soil in 2008, uncovered UCC records revealing the full 

extent of UCC’s historical PCB use, and disclosed its findings to federal and state regulators 

in 2012, neither EPA nor WVDEP has yet required any further corrective action. 
17

i. Subsequent ownership of the Site

In 1993, UCC entered into an agreement to sell the Site to OSi Specialties, 

Inc. (“OSi”). Prior to closing, OSi retained Environment Strategies Corporation 

(“ESC”) to conduct environmental due diligence. ESC requested information 

from UCC about materials disposed of at the North Inactive Site, and UCC 

directed ESC to the 1992 workplan it had submitted to the EPA, which 

purported to detail the known contaminants at the site. ESC issued a report 

which included five paragraphs on PCBs, three of which address PCBcontaining electrical equipment. The other two paragraphs discuss soil samples 

collected in 1992 and 1993 which showed the presence of PCBs, but not at a 

level requiring remediation under EPA guidelines. 

After the sale, the RCRA permit for the Site transferred to OSi. In 1994, 

OSi submitted to the EPA a Corrective Measures/Stabilization Proposal for the 

North Inactive Site, which summarized the corrective actions that had 

previously been taken to control surface water infiltration and runoff from the 

North Inactive Site — including the earthen cap and diversion ditch UCC had 

built in 1992 — and proposing the construction of an interceptor trench to 

divert water away from the North Inactive Site and continued monitoring and 
18

maintenance of the site. EPA approved the proposal in June 1994, and OSi 

constructed the interceptor trench in the fall of 1994. In 1997, EPA modified the 

Site’s permits to recognize that it was satisfied with the measures being taken 

to remedy contamination at the North Inactive Site and to require continued 

inspection and maintenance of the earthen cap and the diversion ditches. 

In 2003, OSi, which had become Crompton Corporation, sold the Site to 

an affiliate of General Electric, Inc., (“GE”), then named GE Advanced 

Materials, which would later become Plaintiff MPM Silicones. The purchase 

agreement included indemnity provisions relating to environmental 

contamination at the Site. Prior to the sale to GE, OSi/Crompton again retained 

ESC to perform an environmental site assessment. After conducting site visits 

and interviews, ESC issued a report stating that the Site had obtained “PCB 

free” status following the removal of all PCB-containing electrical equipment

in 1991. Sp. App’x 93. The report also acknowledged a previous UCC memo 

recognizing the possibility that PCBs had been disposed of at the North 

Inactive Site but noting that UCC’s site monitoring could not substantiate the 

existence of buried PCB wastes. 
19

GE hired ENVIRON, an environmental consulting firm, to conduct a 

review of the site prior to the sale. John Wood, a GE employee who supervised 

ENVIRON’s environmental due diligence, testified (at his deposition during 

the proceedings in the district court) that UCC employees told him about the 

investigation in the 1980s that had raised the possibility of PCB disposal at the 

site, but had assured him that UCC’s site monitoring could not substantiate 

that theory. Wood also testified that UCC employees had told him that UCC 

had used PCB-containing electrical equipment at the Site — which had since 

been removed — and that they believed that “the source of PCBs . . . found at 

the site was leaks from or maintenance [of that electrical equipment].” Dist. Ct. 

Dkt. 89-9 at 5–6. Wood further testified that UCC did not reveal “anything in 

[the] documents or [the] interview process that would have led [GE] to know 

that PCBs were used in the manufacturing process,” and that, had he and his 

team known about this history, they would have “tailored the investigation 

and sampling program in a way that we would have collected more samples, 

specifically trying to address that issue or that area of concern.” Id.

ENVIRON conducted extensive soil and groundwater testing at the Site 

in May 2003. ENVIRON’s final report, issued in May 2004 (after the sale of the 
20

property closed in July 2003), noted that PCBs had been found in 

concentrations exceeding federal regulatory thresholds in groundwater and 

soil samples from various areas in the north end of Sistersville — including 

Sugar Camp Run — and that these positive PCB results were “unexpected.” 

Dist. Ct. Dkt. 80–17 at 74.10 The report explained that prior reports of PCB-laden 

waste dumping at the Site had been dismissed based on a 1992 UCC 

memorandum determining — without explanation — that positive PCB results 

had been “determined not to be valid,” and based on statements from UCC 

representatives that UCC’s “distillation process would not produce PCBs.” Id.

at 11–12. The report, however, further stated:

Although Facility representatives are no longer concerned about 

PCBs in the North Inactive Area, unexpected levels of PCBs were 

found in some Facility soils and selected ground water samples 

during the Phase II investigation. As there is no obvious source for 

these PCBs, resampling of ground water, and further investigation 

of soil, is suggested.

10 PCBs were detected above regulatory levels in soil samples from certain hazardous waste 

storage areas, and in the facility’s waste incineration area at the north end of the site, leading 

ENVIRON to conclude that “further evaluation of this area is required to identify options of 

remediation.” Dist. Ct. Dkt. 80-17 at 40–43. PCBs were also detected in Sugar Camp Run 

sediments in varying concentrations, with “concentrations increas[ing] in the downstream 

direction.” Id. at 48. PCBs were also detected above regulatory thresholds in groundwater 

from the site’s “Environmental Protection Area” in the north end of the site, and in the site’s 

“Fly Ash Disposal Area,” also in the north end of the site “just north of Sugar Camp Run.” Id.

at 45–46, 48–50.
21

Id.; see also id. at 74. In July 2004, GE Advanced Materials sent the May 

2004 ENVIRON report to OSi/Crompton and asserted that under the indemnity 

provisions in the purchase agreement OSi/Crompton was responsible for the 

costs associated with the necessary investigation and remediation of PCBs at 

the Site. OSi/Crompton disclaimed financial responsibility, but nonetheless

engaged ESC to investigate PCB contamination in two areas of the Site: the 

Waste Incineration Area and the Permitted Hazardous Storage Waste Area —

both of which are in close proximity to the North Inactive Site. ESC issued a 

final report on May 30, 2006, concluding that PCB levels in certain areas of the 

site exceeded federal regulatory levels, and recommended “a second phase of 

soil characterization to delineate the vertical and horizontal extent of PCBs in 

soil” in this area. Dist. Ct. Dkt. 80-7 at 13. On August 28, 2007, WSP 

Environmental Strategies delivered a plan for additional sampling, which GE 

Advanced Materials (now named MPM Silicones, LLC) did not implement. 

ii. MPM discovers buried PCBs

In June 2008, during construction of a project to upgrade the site’s 

wastewater treatment unit, MPM uncovered discolored soils which, when 
22

analyzed, were revealed to be contaminated with PCBs. MPM suspended its 

construction project and spent $123,195.05 in response to its discovery. This 

included $30,385.18 disposing of the contaminated materials it had uncovered; 

$8,714.71 decontaminating rented construction equipment; and $84,095.16 on 

steel shoring it needed to prevent the excavated area from caving in. 

In August 2008, MPM contacted OSi/Crompton (then known as 

Chemtura) informing it of the recently discovered contamination and again 

asserting that OSi/Crompton was responsible for the costs of remediation. 

OSi/Crompton again disclaimed responsibility under the indemnity provisions 

of the purchase agreement. In June 2009, MPM hired Clean Harbors, an 

environmental consulting firm, to conduct further sampling in the wastewater 

treatment unit area. Clean Harbors uncovered additional contamination and 

reported that it could not yet determine the geographical extent of the 

contamination. MPM incurred costs of $251,345.20 in connection with Clean 

Harbors’ sampling activities, bringing its total outlays in response to its 

discovery of PCBs to $374,540.25. After receiving the results from Clean 

Harbors, MPM searched the Site’s records and found UCC documents dating 
23

back to 1970 that indicated that UCC had purchased and used “significant 

quantities” of PCBs at the Site. Sp. App’x 105.

MPM has not conducted any further soil sampling or any further 

construction work on its construction of the wastewater treatment upgrade 

since Clean Harbor concluded its sampling in September 2009. MPM, however, 

plans to resume the wastewatertreatment upgrade by installing a pump station 

in the location where it encountered PCBs in 2008, which will require MPM to 

excavate and dispose of the PCB-containing soils. 

MPM contacted UCC regarding the PCB contamination in September 

2010, and the parties entered into a tolling agreement which tolled the statute 

of limitations from May 19, 2011 to December 30, 2011. MPM reported its 

discovery of the PCB contamination to the West Virginia Department of 

Environmental Protection (“WVDEP”) in March 2012. As of September 2017, 

neither WVDEP nor the EPA had required any further remediation of the PCB 

contamination.11

11 MPM has prepared a soil management plan in anticipation of its excavation of the area 

around the wastewater treatment plant, which WVDEP has approved for “advance[ment] to 

the final stage.” Sp. App’x 107.
24

iii. Procedural History

MPM filed this suit on December 30, 2011 seeking, inter alia,

reimbursement under CERCLA from UCC for $374,540.25 in past cleanup 

costs, and a declaratory judgment of UCC’s liability for any future cleanup 

costs required to deal with contamination at Sistersville. 12 UCC brought 

crossclaims seeking contribution under CERCLA, arguing that MPM should 

bear a portion of the response costs.13 

Like RCRA, CERCLA was enacted to “address the risks associated with 

the improper storage and disposal of hazardous and toxic substances.” Schaefer 

v. Town of Victor, 457 F.3d 188, 190 (2d Cir. 2006). CERCLA’s “dual goals [are] 

cleaning up hazardous waste and holding polluters responsible for their 

actions.” New York v. Next Millennium Realty, LLC, 732 F.3d 117, 124 (2d Cir. 

12 MPM brought CERCLA claims against UCC for recovery of costs under Section 107 and for 

declaratory relief as to future costs under Section 113(g)(2), and further asserted state law 

claims of negligence, strict liability, and restitution. 

13 UCC asserted counterclaims for contribution under Section 113(f)(1) of CERCLA and 

declaratory relief under Section 113(g)(2) of CERCLA and the Declaratory Judgment Act, 28 

U.S.C. § 2201. 
25

2013). 14 Among other measures, CERCLA “authoriz[es] private parties to 

pursue contribution or indemnification from potentially responsible parties for 

expenses incurred responding to environmental threats.” Commander Oil Corp. 

v. Barlo Equip. Corp., 215 F.3d 321, 326 (2d Cir. 2000). 15 Section 107(a) of 

CERCLA provides a cause of action for private parties to seek recovery of costs 

from a “potentially responsible party”16 of “any [] necessary costs of response” 

to a release of hazardous substances. Schaefer, 457 F.3d at 195; see also 42 U.S.C. 

§ 9607(a). Section 113(g)(2) permits a party to seek a declaratory judgment on a 

potentially responsible party’s liability for any necessary future response costs. 

14 See also H.R. Rep. No. 99–253 (III), 99th Cong., 1st Sess. 1985, reprinted in 1986 U.S.C.C.A.N. 

3038, 3038 (“CERCLA has two goals: (1) to provide for clean-up if a hazardous substance is 

release into the environment or if such release is threatened, and (2) to hold responsible 

parties liable for the costs of these clean-ups.”).

15 CERCLA also provides that the federal government “may clean up a contaminated area 

itself” and then “recover its remediation expenses directly from parties responsible for [the] 

pollution.” Schaefer, 457 F.3d at 194–95 (citations omitted); see also State of N.Y. v. Shore Realty 

Corp., 759 F.2d 1032, 1041 (2d Cir. 1985) (“CERCLA authorizes the federal government to . . . 

use Superfund resources to clean up hazardous waste sites and spills . . . [and to] sue for 

reimbursement of cleanup costs from any responsible parties it can locate, allowing the 

federal government to respond immediately while later trying to shift financial responsibility 

to others.”).

16 Section 107(a) of CERCLA enumerates four classes of potentially responsible parties 

(“PRPs”): “(1) owners of facilities with hazardous substances; (2) former owners of facilities 

with hazardous substances; (3) generators of hazardous substances; and (4) transporters of 

hazardous substances.” Schaefer, 457 F.3d at 195 (citing 42 U.S.C. § 9607(a)(1)–(4)).
26

42 U.S.C. § 9613(g)(2). Section 113(f)(1) permits a party which has been sued for 

cost reimbursement under Section 107 of CERCLA to sue other potentially 

responsible parties for contribution. See id. § 9613(f)(1); see also Cooper Indus., 

Inc. v. Aviall Servs., Inc., 543 U.S. 157, 162–63 (2004).

CERCLA’s cost-recovery provision distinguishes between two kinds of 

response projects. “Remedial actions” are “generally long-term or permanent 

containment or disposal programs,” State of New York v. Shore Realty Corp., 759 

F.2d 1032, 1040 (2d Cir. 1985), which are taken “in the event of a release or 

threatened release of a hazardous substance into the environment” and are 

“consistent with [a] permanent remedy.” 42 U.S.C. § 9601(24) (defining 

“remedy” or “remedial action”). “Removal actions,” by contrast, are “typically 

short-term cleanup arrangements,” Shore Realty, 759 F.2d at 1040, which 

respond to immediate threats to the environment. 42 U.S.C. § 9601(23) (defining 

“removal”); New York State Elec. and Gas Corp. v. FirstEnergy Corp., 766 F.3d 212, 

230 (2d Cir. 2014) (“NYSEG”) (“Removal actions are generally clean-up 

measures taken in response to immediate threats to public health and safety.”). 

Section 113(g)(2) of CERCLA provides different statutes of limitations for 

lawsuits brought to recover costs for removals and remediations. See 42 U.S.C. 
27

§ 9613(g)(2). A cost recovery suit for a removal must be brought “within 3 years 

after completion of the removal action,” while a cost recovery suit for a 

remediation must be brought “within 6 years after initiation of physical on-site 

construction of the remedial action.” Id.

The parties cross-moved for summary judgment. UCC argued, inter alia,

that MPM’s Section 107 claim for reimbursement of past remediation costs (and 

its Section 113(g)(2) claim for a declaratory judgment on UCC’s liability for 

future remediation costs) were time-barred because previous corrective actions 

taken at Sistersville — specifically, UCC’s installation of a recovery well in 1991 

and its construction of the earthen cap and diversion ditch in 1992, and 

OSi/Crompton’s construction of the interceptor trench in 1994 — were 

remediations, so that the commencement of construction of these measures in 

the early 1990s triggered the six-year statute of limitations for remediations. 

iv. The district court’s July 2016 order

The district court’s July 7, 2016 order concluded that UCC’s actions in 

the early 1990s (and OSi’s construction of the interceptor trench in 1994) were 

remediation (rather than removal), based in part on the fact that the EPA had 

incorporated these measures into the “final remedy” for dealing with 
28

contamination at Sistersville. See MPM I, 2016 WL 3962630, at *11–14. (MPM 

challenges this conclusion on appeal, arguing that “UCC’s activities were more 

analogous to removal action than to remedial action.” MPM Br. at 46–50.)

The district court further found that MPM’s claims for reimbursement of 

costs of its past remediations (under Section 107(a)) and its request for a 

declaratory judgment on UCC’s liability for future remediation costs (under 

Section 113(g)(2)) were time-barred. MPM I, 2016 WL 3962630, at *14–19. In so 

holding, the district court relied on a statement in our decision in NYSEG that 

“there can only be one remedial action at any given site.” 766 F.3d at 235. The 

district court characterized the multiple remediation projects — i.e., (i) UCC 

and OSi’s corrective actions in the early-1990s, (ii) any efforts undertaken by 

MPM to dispose of the PCB-contaminated soil in 2008 that were remedial in 

nature, and (iii) any future remediation efforts MPM would undertake to 

decontaminate the Site — as part of the Site’s single remediation and held that 

“the statute of limitations [to recover costs for that remediation] began to run 

when [UCC] commenced physical on-site construction of the remedial action 

[in the early 1990s].” MPM I, 2016 WL 3962630, at *14. Because the six-year 

statute of limitations began to run in the early-1990s, the court held that the 
29

limitations “had expired long before the parties’ May 19, 2011 tolling 

agreement,” and that MPM’s claims were time-barred under Section 

113(g)(2)(B). Id.17 (MPM’s principal argument on appeal is that the district court 

erred in holding that these claims were barred by the statute of limitations.)

On that basis, the district court granted UCC’s motion for summary 

judgment to the extent that MPM’s claims sought recovery of costs related to 

any remediation at the Site. Id. at *35. The district court, however, held that UCC 

was liable as a matter of law for past and future costs of removal that MPM had 

undertaken or would undertake at Sistersville. Id. 18 Accordingly, the court 

17 The court rejected MPM’s attempt to distinguish NYSEG on the ground that a prior owner’s 

actions could not trigger the statute of limitations for a claim brought by a subsequent owner, 

holding that, while there was no precedent “in which one party’s initiation of construction of 

the remedial action triggered the statute of limitations for another party,” MPM’s argument 

was foreclosed by the statutory text and our decision in NYSEG. MPM I, 2016 WL 3962630, at 

*14–17. 

The court further rejected MPM’s argument that the statute of limitations should be tolled 

under the doctrine of equitable tolling, holding that “MPM has failed to present evidence 

showing that it has pursued its rights diligently” because MPM had failed to take action after 

receiving the May 2004 ENVIRON report recommending further testing for PCBs at the site. 

Id. at *17–19. (MPM challenges each of these conclusions on appeal. MPM Br. at 16–45.)

18 The district court found that at least some of MPM’s response costs were “necessary” and 

“consistent with the national contingency plan,” as required for cost recovery under Section 

107(a)(4)(B). MPM I, 2016 WL 3962630, at *20–25. Further, the district court rejected the 

argument that UCC was not liable for any future response costs associated with an area of 

the Site referred to as Landfill No. 2 because that landfill was a separate “facility,” holding 

that Landfill No. 2 and the other solid waste management units at the site “constitute one 
30

entered a declaratory judgment as to UCC’s liability for the costs of future 

“removal actions” at Sistersville. Id. at *31.19 In a later order, the district court 

granted UCC’s motion for summary judgment that MPM was liable under 

Section 113(f)(1) in contribution for an equitable share of the response costs —

leaving open the issue of cost allocation between MPM and UCC.20 The parties 

subsequently reached a settlement of MPM’s claim for past removal costs. After 

the settlement, the only remaining issue was the allocation of financial 

responsibility for any future removal costs. 

v. The district court’s September 2017 order

CERCLA facility.” Id. at *25–27. (Neither of these conclusions are disputed by the parties on 

appeal.)

19 The district court held that MPM’s state-law strict liability and negligence claims are barred 

by the applicable statute of limitations and declined to grant UCC’s motion for summary 

judgment on MPM’s restitution claim and its claim for a declaratory judgment as to 

restitution. See MPM I, 2016 WL 3962630, at *32–35. (Neither of these conclusions are disputed 

on appeal.). The parties later stipulated to the dismissal of MPM’s restitution claim. Dist. Ct. 

Dkt. No. 202.

20 In its July 7, 2016 order, the district court had denied UCC’s motion for summary judgment 

on its counterclaim under Section 113(f)(1) of CERCLA seeking contribution from MPM of 

past removal costs — and its counterclaim seeking a declaratory judgment on MPM’s liability 

for any future removal costs — after finding that MPM raised a triable issue of fact regarding 

its bona fide prospective purchaser defense. See MPM I, 2016 WL 3962630, at *27–31; 42 U.S.C. 

§ 9607(r)(1) (limiting liability for “bona fide prospective purchaser[s]”); id. § 9601(40) 

(defining “bona fide prospective purchaser”). The district court revisited the issue in a 

December 8, 2016 oral order granting summary judgment to UCC on the issue of MPM’s 

liability for contribution. See MPM II, No. 1:11-cv-1542, Dkt. No. 165.
31

From January 31, 2017 to February 2, 2017, the district court held a bench 

trial on the remaining issues: (a) whether future response costs should be 

allocated and (b) what the parties’ equitable shares of those response costs 

should be. In a September 22, 2017 order, the district court held that the issue 

of allocation of costs was ripe for adjudication because MPM had established 

that “it is likely to incur future costs in responding to PCBs at the Site because 

MPM plans to upgrade its wastewater treatment facilities” which will require 

that “MPM respond appropriately to PCBs in the soils.” MPM III, 2017 WL 

6408611, at *15–18. UCC argues on appeal that the district court erred in so 

holding because the possibility of MPM incurring future removal costs is too 

remote. 

In considering how to allocate future removal costs, the district court 

noted that “UCC was the only entity to bring PCBs onto the Site” and 

“benefitted from disposal of the [PCB] waste” without having to engage in any 

corrective action (factors which weighed in favor of allocating costs to UCC), 

but concluded that there was insufficient evidence to conclude that “UCC’s 

failure to disclose PCBs [to regulators] was driven by an intention to conceal 

information.” MPM III, 2017 WL 6408611, at *19. The court also rejected UCC’s 
32

argument that MPM should bear a majority of future removal costs because 

MPM “had notice of the PCBs and assumed the risk of future PCB-related 

response costs when it acquired the Site,” instead crediting Wood’s testimony 

that, during the due diligence process, UCC employees led him to believe that 

“any PCB contamination was due to PCB electrical equipment.” Id. at *20. 

Further, the court rejected UCC’s argument that the indemnity agreement 

between MPM and Crompton warranted allocating responsibility to MPM, 

finding that “MPM has not been indemnified, nor is there any reason to 

conclude that it will be” because “Crompton has disclaimed responsibility 

under the indemnity agreement.” Id. at *21. The court also rejected the 

argument that MPM should bear the majority of the responsibility because it 

would “derive commercial benefit from any future removal action when it 

upgrades the wastewater treatment unit,” holding that “there is no evidence 

that MPM would realize a meaningful increase in property value as a result of 

a PCB cleanup.” Id.

The court, however, faulted MPM for failing to contact government 

regulators after discovering PCB-contaminated soil in 2008, and for waiting 

until 2012 to inform WVDEP of this development, noting that the Site’s RCRA 
33

permit required MPM to notify regulators of any “relevant facts” regarding 

newly-discovered contamination within seven days of discovery. Id. at *20–21. 

Accordingly, the court allocated five percent of future removal costs to MPM 

and allocated the remaining ninety-five percent of future removal costs to 

UCC. Id. at *1. 21 (On appeal, UCC argues that the district court abused its 

discretion in weighing the relevant allocation factors, and that the district court 

should have allocated more of the cost burden to MPM.)

B. DISCUSSION

MPM argues in this appeal that the district court erred in concluding that 

MPM’s claims for reimbursement of remediation costs are time-barred by §

113(g)(2)(B). UCC contends that the district court erred in determining that 

future allocation of removal costs was ripe for review, and further erred in 

allocating 95% of those costs against it. 

i. Statute of Limitations

21 Because of its prior order holding MPM’s claim for reimbursement of costs for “remedial 

actions” to be time-barred, the district court did not allocate costs related to any future 

remedial actions.
34

MPM directs its arguments against two aspects of the district court’s 

finding of untimeliness: (1) the court’s conclusion that UCC’s prior response 

projects in the 1990s were in the nature of remediation, rather than removal; 

and (2) its conclusion that, if UCC’s prior response projects constituted 

remediation, the six years allowed by § 113(g)(2)(B) for recovery of the costs of 

any further remediation at the Site began to run upon UCC’s initiation of its 

remediation in 1992 and expired in 1998, long before MPM purchased the Site. 

The district court reached the latter conclusion based on its understanding of 

our NYSEG opinion to mean that, once any remediation is undertaken at a site, 

all future remedial activity at the site, regardless of circumstances, is deemed 

to be part of the same initial remediation, so that, under § 113(g)(2)(B), the 

opportunity for timely suit to recover the costs of future remediation at the site 

necessarily expires, absent tolling, six years from the start of the initial 

remediation. 

We agree with the district court that UCC’s corrective actions 

undertaken in the 1990s were remediation, but we do not understand NYSEG

to mean that, for purposes of determining the timeliness of a cost recovery 

action, all remediation activity at a site regardless of circumstances is deemed 
35

to be part of a single remediation, so that the six year limitations period 

necessarily begins to run at the start of the first remedial activity. Accordingly, 

we believe the district court’s conclusion that MPM’s suit was untimely was 

based on an inaccurate premise. We do not decide whether MPM’s suit to 

recovery remediation costs was in fact timely, but instead vacate the district 

court’s decision and remand for reconsideration consistent with this opinion.

The distinction between “removal” actions and “remedial action[s]”

arises from the first iteration of the CERCLA statute enacted in 1980. See Pub. 

L. 96–510, § 101(a)(23)–(24); 94 Stat. 2767, 2770–71 (1980) (defining “remove” or 

“removal” and “remedy” or “remedial action”). The statute defines “remove” 

or “removal” as:

the cleanup or removal of released hazardous substances from the 

environment, such actions as may be necessary [] in the event of 

the threat of release of hazardous substances into the environment, 

such actions as may be necessary to monitor, assess, and evaluate 

the release or threat of release of hazardous substances, the 

disposal of removed material, or the taking of such other actions 

as may be necessary to prevent, minimize, or mitigate damages to 

the public health or welfare or to the environment, which may 

otherwise result from a release or threat of release.

Further, the statute provides several examples of “removal” actions, 

including:
36

security fencing or other measures to limit access, provision of 

alternative water supplies, temporary evacuation and housing of 

threatened individuals not otherwise provided for.

42 U.S.C. § 9601(23). 

The statute defines “remedy” or “remedial action” as:

those actions consistent with permanent remedy taken instead of 

or in addition to removal actions in the event of a release or 

threatened release of a hazardous substance into the environment, 

to prevent or minimize the release of hazardous substances so that 

they do not migrate to cause substantial danger to present or 

future public health or welfare or the environment.

The statute also provides an illustrative list of “remedial action[s],” 

including:

such actions at the location of the release as storage, confinement, 

perimeter protection using dikes, trenches, or ditches, clay cover, 

neutralization, cleanup of released hazardous substances and 

associated contaminated materials, recycling or reuse, diversion, 

destruction, segregation of reactive wastes, dredging or 

excavations, repair or replacement of leaking containers, collection 

of leachate and runoff, onsite treatment or incineration, provision 

of alternative water supplies, and any monitoring reasonably 

required to assure that such actions protect the public health and 

welfare and the environment. The term [also] includes the costs of 

permanent relocation of residents and businesses and community 

facilities [where] such relocation is more cost-effective [than other 

remedial action] . . . [and also] includes offsite transport and offsite 

storage, treatment, destruction, or secure disposition of hazardous 

substances and associated contaminated materials.

Id. § 9601(24). 
37

The statutory definitions do not provide clear insight as to the boundary

between removals and remediations. The definitions of each type of action 

overlap substantially: certain corrective actions — like covering contaminated 

soil or diverting water away from contaminated areas with drainage controls,22

the provision of alternative water supplies to replace contaminated water,23

and related monitoring activities24 — may be classified as either “removal” or 

“remedial” actions. Over several decades of CERCLA litigation, courts have 

agreed on a general principle to distinguish the two: “[r]emoval actions are 

generally clean-up measures taken in response to immediate threats to public 

health and safety” that “address contamination at its endpoint,” while 

“[r]emedial actions are typically actions designed to permanently remediate 

22 See 42 U.S.C. § 9601(24) (listing “trenches,” “ditches,” and “clay cover” as examples of 

“remedial action[s]”); 40 C.F.R. § 300.415(e) (listing “[d]rainage controls, for example, run-off 

or run-on diversion,” and “[c]apping of contaminated soils” as examples of “removal 

actions”).

23 See California ex rel. Cal. Dept. of Toxic Substances Control v. Neville Chemical Co., 358 F.3d 661, 

667 (9th Cir. 2004) (noting that “’provision of alternative water supplies’ is listed as both a 

type of ‘remedial action’ and as a type of ‘removal’”).

24 See Colorado v. Sunoco, Inc, 337 F.3d 1233, 1244–45 (10th Cir. 2003) (explaining that 

monitoring wells could be classified as “removal” or “remedial” under both statutory 

definitions).
38

hazardous waste” that address contamination at its source. NYSEG, 766 F.3d at

230–31. 

The key distinction between the two terms is immediacy and 

comprehensiveness. United States v. W.R. Grace & Co., 429 F.3d 1224, 1244 (9th 

Cir. 2005). Removal actions are undertaken to deal with “threat[s] to human 

health or the environment which require[] an immediate response.” Id.

(citations omitted). 25 Because removal actions are generally targeted at 

reducing the deleterious effects of contamination — e.g. the removal from 

downstream water supply wells of contaminants that have migrated from a 

nearby landfill, see Next Millenium, 732 F.3d at 126–27 — they are generally not 

so ambitious as to seek to eliminate or permanently contain the source of 

contamination. They do not generally aim to serve as permanent solutions. See, 

e.g., NYSEG, 766 F.3d at 231–33 (characterizing efforts to “clean[] up coal tar 

that had already migrated from [the source of contamination]” and to “remove 

25 See also Barmet Aluminum Corp. v. Reilly, 927 F.2d 289, 291 (6th Cir. 1991) (“Removal refers 

to short-term action taken to halt any immediate risks posed by hazardous wastes.”); 40 C.F.R. 

§ 300.415(b)(2) (listing various public health hazards like “exposure to nearby human 

populations, animals, or the food chain from hazardous substances or pollutants or 

contaminants” as factors to be considered in determining the appropriateness of a removal 

action).
39

[coal tar] from [a] river” as “removal actions” because those efforts were “not 

designed to clean up contamination at the source”); id. at 233 (“[M]easures 

taken to minimize and mitigate contamination, but not to permanently 

eliminate it, are properly classified as removal actions.”) (citation omitted).

Removals are often planned and executed relatively quickly in order to 

immediately abate public health hazards, such as contaminated drinking 

water.26 Accordingly, removals are often undertaken to secure prompt relief 

from a danger even though the action is not deemed a step toward permanent 

elimination of the threat. See, e.g., Colorado v. Sunoco, Inc., 337 F.3d 1233, 1244 

(10th Cir. 2003) (holding that the plugging of a mine was a “removal” action in 

part because, when the plug was installed, “it was uncertain whether the 

plugging would achieve the goal of eliminating [contamination]”).27 In essence, 

26 See Next Millenium, 732 F.3d at 126–29 (holding that two measures designed to “remove 

sufficient amounts of contamination from polluted water to render the water safe to drink” 

were “removal actions”); City of Moses Lake v. United States, 458 F. Supp. 2d 1198, 1213 (E.D. 

Wash. 2006) (action to address contamination and restore safe drinking water “bears all of the 

hallmarks of a ‘removal action’ — an interim response to minimize and stabilize imminent 

harms to human health”).

27 See also id. at 1245 (holding that the installation of monitoring wells was a “removal” action 

because the “wells were installed so that the EPA could determine . . . whether the plugging 

was effective in reducing the level of contamination in the water”).
40

because removals “can be initiated promptly after notification of a threat,” they 

provide “flexibility to tailor prompt and effective responses to immediate 

threats to human health and the environment.” W.R. Grace, 429 F.3d at 1226, 

1240.

Remediations, by contrast, include only actions “consistent with [a] 

permanent remedy.” 42 U.S.C. § 9601(24). Remediations are undertaken to 

permanently remediate contamination, generally after months (if not years) of 

correspondence with regulators, soil testing, data collection, safety and quality 

control analysis, and feasibility studies. See 40 C.F.R. § 300.430(a)(2) (describing 

the process of compiling a remedial investigation/feasibility study, which 

“includes the following activities: project scoping, data collection, risk 

assessment, treatability studies, and analysis of alternatives”). See generally id. 

§ 300.430 (describing the process a regulatory agency must undertake before 

approving or implementing a remedial action program). Unlike removals, 

remediations generally presuppose full disclosure has been made to the 

regulator of the “scope and complexity of the site problems being addressed,” 

id. § 300.430(a)(ii)(C); see also 42 U.S.C. § 9603(c), so that the remediation may 

serve as a “final, once-and-for-all cleanup of a site” designed to cost-effectively
41

remediate the full scope of those known problems. NYSEG, 766 F.3d at 236.

Unlike removals, remediations typically address “the underlying source of the 

contamination.” Id. at 233 (citation omitted) (characterizing a 1980s cleanup to 

prevent coal tar that had migrated from its source from “further migrating into 

[a] river” — taken as “an immediate response to a health concern” about water 

contamination — as a removal action, but characterizing later work to excavate 

the source of the coal tar contamination as a remediation because it was 

“designed to remediate the pollution at its source”).

Moreover, CERCLA and its implementing regulations provide a 

pathway to “transition from a removal to a remedial action if it [is]

‘determine[d] that the removal action will not fully address the threat posed by 

the release.’” W.R. Grace, 429 F.3d at 1242–43 (quoting 40 C.F.R. § 300.415(g)). 

In other words, removal actions initially undertaken to respond to immediate 

threats may be adopted as part of a permanent remedial solution. See, e.g. Next 
42

Millenium, 732 F.3d at 128–29 (noting that two removal measures “were 

ultimately adopted as part of a permanent remedial solution”).28

As passed in 1980, CERCLA did not contain a statute of limitations 

applicable to cost recovery actions under Section 107. See Merry v. Westinghouse 

Elec. Corp., 684 F. Supp. 852, 856 (M.D. Pa. 1988); United States v. Mottolo, 605 F. 

Supp. 898, 909–10 (D.N.H. 1985).29 In 1986, Congress passed the Superfund 

Amendments and Reauthorization Act of 1986 (“SARA”), Pub. L. 99–499, 100 

Stat. 1613, which implemented separate statutes of limitations for removals and 

28 Accordingly, while Section 113(g)(2) requires that a suit to recover the costs of a removal 

action be filed “within 3 years after completion of the removal action,” it further provides that 

“if the remedial action is initiated within 3 years after the completion of the removal action, 

costs incurred in the removal action may be recovered in the cost recovery action” brought 

under the provision for cost recovery of remedial action costs. 42 U.S.C. § 9613(g)(2)(B). In 

other words, when a party transitions from undertaking removal action to undertaking 

remedial action by adopting and commencing construction of a permanent remedial solution, 

that party may bring suit to recover the costs of all its actions — whether removal or remedial 

— at any time “within 6 years after initiation of physical on-site construction of the remedial 

action.” Id.; see also H.R. Rep. No. 99–253(III), at 21 (1985) (House Judiciary Comm. Report) 

(“If a remedial action is commenced within three years of the completion of a removal action, 

costs incurred in the removal action may be added to those sought for the remedial action. In 

other words, there is no intention to mandate separate cost recovery actions for removal and 

remedial actions so long as they follow each other within a three year time period.”).

29 To evaluate the timeliness of cost-recovery claims in the absence of a statutory limitations 

period, courts applied an analogous state or federal statute of limitations or the doctrine of 

laches. See Mottolo, 605 F. Supp. at 909.
43

remediations. See 42 U.S.C. § 9613(g)(2). 30 Section 113(g)(2) of CERCLA, as 

amended by SARA, now provides:

An initial action for recovery of the costs referred to in [Section 

107] must be commenced—

(A) for a removal action, within 3 years after completion of the 

removal action . . . 

(B) for a remedial action, within 6 years after initiation of 

physical on-site construction of the remedial action . . . .

42 U.S.C. § 9613(g)(2). The legislative history does not explain why 

Congress took a different approach to limitation periods as between removals 

and remediations.31

30 See H.R. Rep. No. 99–253 (III), 99th Cong., 1st Sess. 1985, reprinted in 1986 U.S.C.C.A.N. 3038, 

3043–44 (explaining that the Committee on the Judiciary “believes that cost recovery . . . 

actions should be brought at the most appropriate time in light of the response action taken” 

and discussing the statutes of limitations in SARA).

31 Several early versions of the bill as considered by both the Senate and the House of 

Representatives contemplated a single statute of limitations period for all cost recovery 

actions under Section 107(a): six years from the “completion of the response action.” See 

Hearing on Reauthorization of Superfund Before Subcomm. On Commerce, Transportation, and 

Tourism of the H. Comm. On Energy and Commerce, 99th Cong. 65, 107–08 (March 1985) (noting 

that the draft bill would “establish[] a six-year statute of limitations for the filing of cost 

recovery actions” to run from the “completion of any operation and maintenance activities”) 

(EPA’s Proposed Amendments to CERCLA); S. Rep. No. 99–11, at 54–55 (March 1985) (Senate 

Comm. on Environment and Public Works) (noting that the bill under consideration would 

provide for a statute of limitations of “6 years after the date of completion of the response 

action”). By October 1985, the House considered and proposed a new version of the bill 

“distinguish[ing] between remedial actions and removal actions” for statute of limitations 

purposes, see H.R. Rep. 99–962 at 223 (1986), providing for a three-year statute of limitations 
44

a. UCC’s construction of the earthen cap and the diversion ditch in 1992 were 

remedial 

MPM argues on appeal that UCC’s construction of an earthen cap and 

diversion ditch for the North Inactive Site (and OSi/Crompton’s construction 

of a different interceptor trench in 1994) were removals rather than 

remediations because those actions are similar to actions that this court held in 

Next Millenium and NYSEG to be removals.32 In Next Millenium, however, we 

classified two measures — a “granulated activated carbon adsorption system” 

and an “air stripper tower,” both designed to remove volatile organic 

compounds from water supply wells in order to decontaminate drinking 

water, 732 F.3d at 122 — as removals in part because “both systems were 

installed in response to an imminent public health hazard,” which we noted 

for removal actions, to run from the “completion of the removal action,” and a three-year 

statute of limitations for remedial actions, to run from “the commencement of physical onsite construction of the remedial action, that is, after the RI/FS and after design of the remedy.” 

H.R. Rep. No. 99–253(III), at 21 (1985) (proposing this change). By October 1986, the House 

version of the bill had been amended to extend the statute of limitations for remedial actions 

from three years to “6 years after initiation of physical on-site construction of the remedial 

action.” See H.R. Rep. 99–962, at 39 (1986). That language is reflected in the enacted version 

of SARA. See Pub. L. 99–499, 100 Stat. 1613, 1649 (Oct. 17, 1986).

32 MPM also argues that these actions were not “consistent with a permanent remedy” as 

required by the definition of “remedial action” under 42 U.S.C. § 9601(24) because the actions 

did not deal with PCB contamination at the Site by reason of UCC’s failure to disclose that 

problem to regulators. 
45

was “a defining characteristic of removal actions.” Id. at 126. Moreover, the 

Next Millenium court noted that both measures “were designed . . . to address 

water contamination at the endpoint — the wells — and not to permanently 

remediate the problem by ‘prevent[ing] or minimiz[ing] the release of 

hazardous substances so that they do not migrate’ from the underlying source 

of contamination.” Id. at 127 (quoting 42 U.S.C. § 9601(24)). The measures were, 

in other words, a “respon[se] to a water-supply problem, not an environmental 

cleanup concern” because they dealt with mitigating the effects of 

contamination, rather than eliminating or containing the source of 

contamination (which, in Next Millenium, was contamination at a nearby 

hazardous waste site). Id.

In contrast, each of the measures taken by UCC and OSi/Crompton to 

deal with the North Inactive Site in the 1990s were clearly remedial in nature. 

Neither the 1992 earthen cap, nor the 1992 diversion ditch, nor the 1994 

interceptor trench were efforts to deal with any “imminent” hazard or threat to 

public safety by neutralizing contamination “at its endpoint.” See NYSEG, 766 

F.3d at 231. There is no suggestion in the record that the contamination at 

Sistersville had caused any kind of time-sensitive threat that “required an 
46

immediate response.” W.R. Grace & Co., 429 F.3d at 1244 (citation omitted); see 

id. at 1245 (concluding that “removal actions encompass interim, partial timesensitive responses taken to counter serious threats to public health”). Rather,

these actions were taken as steps to permanently prevent contaminants known 

to be buried at the North Inactive Site from migrating away from their source 

— i.e., the location of their burial. Such “permanent containment” measures are 

remedial in nature. Schaefer, 457 F.3d at 195; id. at 204 (holding that the 

construction of an earthen cover to close a landfill was a remediation); see also 

42 U.S.C. § 9601(24) (defining “remedial action[s]” as those taken “to prevent 

or minimize the release of hazardous substances so that they do not migrate,” 

and listing “trenches,” “ditches” and “clay cover” as examples of “remedial 

action[s]”); W.R. Grace & Co., 429 F.3d at 1238–39 (noting that the definitions of 

“remedial action” and “removal” overlap, but that the “definition of ‘remedial 

action’ . . . can be distinguished from ‘removal’ because it refers to ‘permanent’ 

remedies . . . [while] ‘removal’ is focused on temporary and emergency 

activities”).33 We conclude that the district court did not err in holding that 

33 To be sure, capping contaminated soil may also be characterized as a “removal action.” See 

40 C.F.R. § 300.415(e)(4). 
47

UCC’s construction of the earthen cap and the diversion ditch in 1992, and 

OSi/Crompton’s construction of the interceptor trench in 1994, qualified as 

remediations under CERCLA.

b. NYSEG’s single-remediation principle was not intended to govern all 

circumstances

The district court concluded that MPM’s claims for reimbursement of the 

costs of its remediation are time-barred by reason of UCC’s prior remediation, 

which began more than six years before MPM brought suit. The district court 

believed this conclusion was compelled by a statement in our NYSEG opinion, 

which signed on to a proposition asserted by the Tenth Circuit (and some other 

courts) that “there can only be one remedial action at a site.” 766 F.3d at 236.34

We believe for reasons explained below that this misinterpreted our NYSEG 

ruling. 

The NYSEG opinion, as relevant here, considered whether the plaintiffs’ 

cost-recovery claims, brought in 2003, were barred by 42 U.S.C. § 9613(g)(2), 

the same statute of limitations provision that applies here. NYSEG, 766 F.3d at 

34 See Sunoco, 337 F.3d at 1241 (“[CERCLA’s language] indicates there will be but one ‘removal 

action’ per site or facility, as well as a single ‘remedial action’ per site or facility.”).
48

221. The plaintiff was the operator of two sites, Norwich and Owego, which 

had been contaminated by the defendant, a prior operator of the site.35 At the 

Norwich site, the plaintiff had undertaken a three-phase “Interim Remedial 

Measure,” planned in consultation with the governmental regulatory agency 

to take place in 1993 (Phase I), 1996 (Phase II), and April 1997 (Phase III). Id. at 

234. The 2003 suit sought to recover the costs of Phase III only, presumably 

because a suit to recover the costs of Phases I and II would clearly have been

barred as more than six years had elapsed from the beginning of those phases. 

Id.; 42 U.S.C. § 9613(g)(2); see also New York State Elec. & Gas Corp. v. FirstEnergy 

Corp., 808 F. Supp. 2d 417, 427 (N.D.N.Y. 2011) (“NYSEG Dist. Ct. Op.”). The 

defendant contended the suit was barred, even as to the 1997 phase, because 

the six years allowed began to run at the start of the remediation in 1993. The 

plaintiff argued that its suit was not barred because the 1997 phase of the 

cleanup was a discrete project, distinct from the prior phases, so that its 

35 The NYSEG opinion also considered the timeliness of the plaintiff’s cost recovery claim for 

a response project at a third site at Plattsburgh. Id. at 231–33. The court upheld the district 

court’s finding that, because earlier clean-up action was “more akin to a removal than a 

remedial action,” that earlier response effort did not trigger the statute of limitations for 

claims to recover remedial action costs. Id. at 233.
49

inception in 1997 started a new allowable six years for a cost-recovery suit.36

NYSEG, 766 F.3d at 234. Rejecting that argument, this court affirmed the district 

court’s finding that the three-phase cleanup was “one remedial cleanup,” 

relying, in part on the plaintiff’s having stipulated that the three stages of the 

project were a “single action comprised of three phases.” Id.

At the one-acre Owego site, the plaintiff undertook to eliminate coal tar 

contamination between September 1994 and 1995 (the “1994 response”). Id. at 

235. After discovering additional coal tar contamination and the pipe that was 

the source of that contamination, the plaintiff undertook additional response

activity in 2003 (the “2003 response”). See NYSEG Dist. Ct. Op, 808 F. Supp. 2d 

at 479; NYSEG, 766 F.3d at 235. The defendant argued that work done in the 

2003 response was a “continuation of the remedial work begun in 1994,” 

NYSEG, 766 F.3d at 235, so that the 2003 suit was time-barred by the passage of 

six years. See 42 U.S.C. § 9613(g)(2). The district court agreed that the claim was 

time-barred, reasoning that the 1994 response and the 2003 response were part 

of the same “remedial” project, in part because both actions addressed “the 

36 The plaintiff also argued unsuccessfully that the 1997 response project should be 

characterized as a removal action, rather than a remedial action. Id. at 234–35.
50

same source and constituent contamination.” NYSEG Dist. Ct. Op., 808 F. Supp. 

2d at 511.37

On review, this court affirmed the district court’s finding of 

untimeliness. NYSEG, 766 F.3d at 235–36. We rejected the plaintiff’s argument 

that the work done in 2003 was a separate and distinct remediation from the 

remedial work done in 1994, see id. at 235; see also Br. for Plaintiff at 45–47 in 

NYSEG, 766 F.3d 212 (No. 11-4143) (2d Cir. 2014), characterizing it rather as a 

continuation of the earlier project.

What we have described above fully explained and justified the NYSEG

court’s conclusion that the suit was time-barred. As further support, however, 

the NYSEG court cited with approval the Tenth Circuit’s statement in Colorado 

v. Sunoco that the CERCLA statute envisages only one “’remedial action’ per 

site.” 337 F.3d at 1242. The district court in the case now before us understood 

that proposition as categorically applicable in all circumstances. MPM I, 2016 

WL 3962630, at *14. For reasons explained below, we believe the NYSEG

37 The district court also rejected the argument that, because the 2003 action was targeted at a 

different “operable unit” than the 1994 action, the actions were separate “remedial actions,” 

in part because the two operable units were “insufficiently distinct to support the application 

of separate limitations periods.” 808 F. Supp. at 511.
51

opinion cannot have intended this proposition to govern every different 

remediation circumstance. The proposition, although altogether reasonable in 

the conventional circumstances to which it was applied in NYSEG, Sunoco, and 

other cases, cannot have been intended to apply in very different 

circumstances, in which application of that proposition would make little 

sense.

In NYSEG, as reviewed above, the plaintiff had undertaken a series of 

remedial steps directed towards remediation of a contamination problem 

perceived at the outset; the subsequent steps were either explicitly foreseen at 

the start of the remediation (Norwich), see NYSEG, 766 F.3d at 234, or at least 

contemplated (Owego), id. at 235; see also NYSEG Dist. Ct. Op., 808 F. Supp. 2d 

at 478 (noting that the regulatory agency had defined the Susquehanna River, 

the site of the subsequent response project, as an operational unit in March 

1994, and that the operator begun an investigation of that operational unit in 

1996). And nothing would have prevented the plaintiff from suing the 

contaminator, both to recover remediation costs already expended, and for a 

declaratory judgment as to liability and allocation of future costs, within the six 

years allowed for such a suit. See 42 U.S.C. § 9613(g)(2) (allowing for a forward-
52

looking claim for a “declaratory judgment on liability for . . . further response 

costs”). As applied to such circumstances, the single-remediation principle

means simply and logically that the plaintiff cannot escape the six-year 

limitation period and endlessly postpone the bringing of suit by characterizing 

subsequent phases of the initial project as new remediations. A plaintiff whose 

suit is time-barred in such circumstances has suffered no unfairness as the 

preclusion was simply the result of the plaintiff’s needless delay.

The several precedents that NYSEG followed in uttering the singleremediation principle similarly involved the same conventional circumstance, 

for which that principle is fair and sensible. The plaintiffs — with at least a 

general awareness of the contamination problems — had undertaken at the 

outset to remedy them. The subsequent stages of response were either (1) 

further steps towards remediating the original problems, see, e.g., California ex 

rel. Cal. Dep’t of Toxic Substances Control v. Hyampom Lumber Co., 903 F. Supp. 

1389, 1390–91 (E.D. Cal. 1995), or (2) steps to remediate different aspects of the 

originally known problem, see, e.g., Sunoco, 337 F.3d at 1237–38. And there was 

no impediment that would have prevented the plaintiffs from suing the 
53

contaminator within six years of initiating the remediation as to both past and 

future remediation work.

In Hyampom, for example, the District Court for the Eastern District of 

California considered a series of steps undertaken by California’s regulatory 

agency to remove contaminated soil from the site of a lumber mill. 903 F. Supp. 

at 1390. Those steps included: (a) the installation, in 1987 and 1988, of fences 

around the contaminated areas; (b) the construction, in September 1988, of 

temporary water and electrical infrastructure in preparation for the excavation 

of the contaminated areas; and (c) the excavation of the contaminated areas 

beginning in October 1988. Id. at 1390–91. There was no question that each of 

these steps were undertaken to remediate the same problem, and to bring about 

the same desired remedy, which the California Department of Toxic Substances 

(the regulator in charge of overseeing the cleanup) had identified in its 

Remedial Action Plan as the “excavat[ion] and remov[al] [of] the contaminated 

soil from the site.” Id. at 1390. There was nothing to prevent the State of 

California, which sought to recover the costs incurred by its regulator (under 

the same CERCLA provision as asserted here by MPM) from bringing a costrecovery suit within six years of the “initiation of physical on-site construction” 
54

of its overall remediation effort. Because California failed to bring the suit 

within six years, it was not timely.

The situation considered in Colorado v. Sunoco involved cleanup activities 

at a former gold mine site that contained contaminated water. 337 F.3d at 1237–

38. The EPA, together with the State of Colorado, took control of the site in 1992 

to deal with multiple environmental threats, including (a) several adits (i.e.

horizontal mine openings for drainage) in the gold mine through which 

“metal-contaminated, acidic water” drained out of the mine and into the 

environment and (b) a “heap leach pad” containing waste treatment sludge 

leftover from mining and waste treatment operations. Id. at 1236–38. The EPA’s 

initial cleanup operations — undertaken in 1994 — included the improvement 

of the water treatment systems that dealt with the contaminated water on the 

“heap leach pad” and the plugging of the mine adits to prevent contaminated 

water from leaking out of the mine. Id. at 1237. The EPA later determined that 

a “permanent sludge disposal area” was required for disposal of the sludge 

from the heap leach pad; it undertook construction of that disposal area 

sometime between 1994 and 1996. Id. at 1238. It is clear that EPA undertook 

each of these steps to deal with the set of issues it set out to remediate when it 
55

took control of the site in 1992, and that each step was a phase in the regulator’s 

effort to bring about its desired “permanent remedy.” 42 U.S.C. § 9601(24) 

(defining “remedial action”).38 There was no reason why the regulator could 

not have brought its suit within six years of the commencement of its response 

project in 1994; its failure to do so until 2001 meant that, as the Tenth Circuit 

38 The other appellate case cited by the NYSEG opinion, Kelley v. E.I. DuPont de Nemours and 

Co., 17 F.3d 836 (6th Cir. 1994), followed a similar pattern. That case concerned a 34–acre 

landfill polluted with large amounts of chemical waste contained in “open or sealed 55–gallon 

drums.” Id. at 838. After determining that the drums contained hazardous waste and 

detecting the presence of other hazardous substances in the groundwater, regulators 

commissioned a contractor, Haztech, to remove surface waste from the site in October 1985. 

Id. As part of that effort, Haztech removed several drums from the surface of a pond that 

“contained bluish colored water.” Id. The regulator simultaneously hired a different 

contractor to perform site evaluation activities, which revealed the presence of additional 

solid waste in the blue-water pond in 1987. Id. at 839. After that discovery, the regulator hired 

a different contractor, Inland Water, to perform further remediation work on the blue-water 

pond, consisting of the removal of additional drums and 1,150 cubic yards of contaminated 

soil. Id. As in Sunoco, there was no question that the 1985 and 1987 response projects were 

directed at the same contamination problem and constituted different “phases” of the 

response action required to bring about the regulator’s desired remedy.

The NYSEG opinion also cited Yankee Gas Servs. Co. v. UGI Utils., Inc., 616 F. Supp. 2d 228 (D. 

Conn. 2009) in support of its single-remediation principle. However, while the court in that 

case noted that “courts have generally held that there can be only one . . . remedial action per 

facility, regardless of the number of phases in which the clean-up occurs,” see id. at 270, that 

statement had no relevance to the court’s holding that several of the claims were time-barred 

because, in that case, all of the response projects under consideration were commenced more 

than six years before the plaintiff filed suit. See id. at 269 (noting that the plaintiff filed suit in 

September 2006); id. at 271 (noting that the most recent response project at the Norwalk site 

was commenced in 1999); id. at 274 (noting that the most recent response project at the 

Willimantic site was commenced in 1997).
56

held, it would have lost the opportunity to take advantage of CERCLA’s costrecovery provisions for remediation.39

In the circumstances of NYSEG (and in the precedents it cites), the singleremediation principle was logical and fair, and it served the designs and 

objectives of RCRA and CERCLA. Although it is a reliable prescription in the 

great majority of cases, we do not believe that our NYSEG panel intended the 

principle to control if the circumstances of a case would render it illogical and 

unfair, and would defeat the statutory design or objectives. 

The most obvious example of inappropriate application of the singleremediation principle would arise when the subsequent remediation

undertakes to remediate a problem that did not exist at the time of the prior 

remedial act. If, following a remediation, the operator of a site creates a 

different contamination, caused by different processes and a different 

39 The Sunoco court ultimately disagreed with the district court’s characterization of the EPA’s 

1994 installation of adit plugs as a “remedial action,” and held instead that those efforts were 

properly characterized as a “removal action.” 337 F.3d at 1243. It remanded the question 

whether the subsequent construction of a sludge disposal area was a removal or a 

remediation. Id. at 1244–46. Because the court held that there was no prior remediation that 

could have barred the regulator’s claim for recovery of its later incurred remedial costs, the 

court’s statement that “there will be but one . . . ‘remedial action’ per site or facility,” id. at 

1241, was dictum that played no role in the decision.
57

contaminating substance, and the burden of remediating that contamination 

falls on a new owner that acquires the site many years later, there would never 

be a moment when the new owner could sue to recover its response costs.

When such future contaminations occurred and became known, future owners 

or operators would be compelled by CERCLA and RCRA to report the 

discovery to government regulators and undertake any remediation that 

regulators may deem necessary, see 42 U.S.C. § 9603(a) (requiring disclosure); 

id. § 6924(u) (instructing regulators to “require[] corrective action for all 

releases of hazardous waste”); see also MPM III, 2017 WL 6408611, at *21 (noting 

that the RCRA permit for the Site required notification to regulators of newlydiscovered contamination within seven days), but any suit to recover the cost 

of such remediation from the contaminator would be untimely by reason of a 

prior remediation decades in the past that had nothing to do with the present 

contamination, then as yet non-existent. We do not believe the NYSEG panel 

intended its single-remediation principle to apply in such a circumstance.

A second less obvious but equally illogical and inappropriate example 

would arise when a site operator discovers a previously unsuspected 

contamination that was unrelated to, and perhaps far distant from, a 
58

previously remediated contamination. Suppose, for example, that the owner of 

a 10,000 acre site in 1990 completely remediated a chemical spill that it had 

caused on a tiny corner of a site. Suppose further that another operator 

acquired the site many years later and discovered a fifty-year-old 

contamination, far distant from, and unrelated to the contamination that had 

been remedied in 1990, and unsuspected at that time. If the single-remediation

principle were to be categorically applied, the new owner, although compelled 

by law to report and remediate, would be unfairly precluded from utilizing 

CERCLA’s cost-recovery mechanism to recover the necessary costs of cleanup 

from the party responsible.

If, in a third scenario analogous to the present case, the original polluter 

implemented an inadequate remediation pursuant to a regulatory approval 

that was procured by inadequate disclosure, and then held the site for six years 

after the misguided project began, a later owner who discovers the 

contamination that the prior remediation failed to address would nevertheless 

be obliged to disclose and remediate it, but could not recover its costs if the 

single-remediation principle were applied. The original polluter would enjoy 

an undeserved immunity as a result of its inadequate disclosure of what 
59

needed to be remediated, and its retention of the site for six years after initiating 

its incomplete remediation.

A categorical single-remediation principle, while logical for the 

conventional pattern of cost-recovery suits, such as NYSEG, would frustrate 

and defeat the efficacy of cost-recovery as an essential motivator in the 

RCRA/CERCLA framework. Without access to cost-recovery suits against 

contaminators, neither private parties nor regulators would be incentivized to 

ensure that cleanups are conscientious and thorough. Cf. Key Tronic Corp. v. 

United States, 511 U.S. 809, 819 n.13 (1994) (“CERCLA is designed to encourage 

private parties to assume the financial responsibility of cleanup by allowing 

them to seek recovery from others.” (internal quotation marks omitted) 

(quoting FMC Corp. v. Aero Indus., Inc., 998 F.2d 842, 847 (10th Cir. 1993))). 

Worse still, an operator who, after taking ownership of a site, discovers 

preexisting contamination, if deprived of access to cost recovery, might conceal 

its discovery from regulators; if it disclosed the contamination, as CERCLA and 

the site’s RCRA permit would require, see 42 U.S.C. § 9603(a); MPM III, 2017 

WL 6408611, at *21, it may be required to undertake catastrophically costly 

remediation at its own expense while the contaminator, which should bear the 
60

costs, enjoys wholly unjustified immunity that results from overbroad 

application of a notion invented by the courts. Overbroad application of the 

single-remediation principle would accordingly undercut CERCLA’s manifest 

purpose to “encourag[e] the timely cleanup of hazardous waste sites” by 

private parties by “placing the cost of that cleanup on those responsible for 

creating or maintaining the hazardous condition.” Consolidated Edison Co. of 

New York, Inc. v. UGI Utils., Inc., 423 F.3d 90, 94 (2d Cir. 2005) (alteration, 

brackets, internal quotation marks, and citation omitted); see also H.R. Rep. No. 

99–253(III), 1986 U.S.C.C.A.N. 3038, 3038 (explaining that one of CERCLA’s 

two primary goals is to “hold responsible parties liable for the cost of 

[necessary environmental] cleanups”).

There is nothing in the words of the statute that invites a categorical

single-remediation principle. Although Sunoco (which NYSEG cited) tried to 

find support within the statute’s wording, see 337 F.3d at 1241, the grammatical 

principle that the court invoked would, under careful examination, support the 

opposite conclusion. 40 Moreover, the fact that neither the statute, nor the 

40 The pertinent sentence of § 9613(g)(2) reads:
61

[F]or a remedial action, [an initial action for recovery of costs must be 

commenced] within 6 years after initiation of physical on-site construction of 

the remedial action, except that, if the remedial action is initiated within 3 years 

after the completion of the removal action, costs incurred in the removal action 

may be recovered in the cost recovery action brought under this subparagraph.

The Tenth Circuit reasoned that the use of the definite article (“the”) in the second clause 

foreclosed the possibility of multiple remedial actions at a site, noting “[i]f Congress intended 

to allow multiple actions for separate components of recovery of remedy, it surely would 

have used the indefinite article ‘a’ rather than the definite article ‘the’ to modify the phrases 

‘removal action’ and ‘remedial action.’” Sunoco, 337 F.3d at 1241. This puts more weight on 

the choice of article than the choice can bear. In any event, this overlooks the fact that, in the 

first usage of the term “remedial action,” the term is preceded by the indefinite article (“a 

remedial action”). The use of the definite article (“the”) in a subsequent reference to “remedial 

action” means that the subsequent reference is to the same “remedial action” as was 

previously mentioned. Suppose that one writes, “When interpreting a statute, courts must 

focus on the statute’s text.” The definite article (“the”) is used in the second reference to 

“statute.” But the first reference used the indefinite article (“a”). The use of “the” in the second 

reference means only that the second reference is to the previously mentioned statute. It does 

not mean that there can be but one statute to which the statement applies. The use of “the

remedial action” in our statute’s second reference serves the same function as using “it” to 

refer to the earlier mentioned remedial action. If Congress had used “the” in its first reference 

to “remedial action,” that would have given arguable support to the Sunoco reasoning, but 

use of “the” following an introductory reference to “a remedial action” gives no support 

whatsoever. If anything, it demonstrates the contrary.

Moreover, the language on which the Tenth Circuit relied was not included in the CERCLA 

bill enacted in 1980, which implemented the definition of “remedial action” that remains in 

force today. That language was enacted six years later, as a part of SARA. See Pub. L. No. 99–

499 (1986). There is no indication that Congress intended this part of SARA, which was 

evidently intended to create a statute of limitations for CERCLA cost-recovery claims where 

none existed before, see Section-by-Section Analysis: EPA’s Proposed Amendments to CERCLA,

99th Cong. 1st Sess, 131 Cong. Rec. 200000-25, 1985 WL 700809, at *28 (Feb. 22, 1985), to modify 

the definition of “remedial action” it had enacted six years earlier so as to foreclose the 

possibility of multiple remedial actions. See Whitman v. Am. Trucking Ass’ns, 531 U.S. 457, 468 

(2001) (“Congress . . . does not alter the fundamental details of a regulatory scheme in . . . 

ancillary provisions—it does not, one might say, hide elephants in mouseholes.”).
62

implementing regulations define the term “site” means that it can be applied 

to large areas, exacerbating the problems that could result from overly broad 

application of the concept. 

For the reasons explained above, we understand the single-remediation 

principle stated in NYSEG to mean that, when a remediation is undertaken 

under a remediation plan based on full disclosure of the known problem, 

successive remedial steps undertaken in furtherance of the original objective 

are part of a single remediation for purpose of the statute of limitations, so that 

the remediator may not delay suit by classifying subsequent stages of 

remediation of the original problem as new remediations. See NYSEG, 766 F.3d 

at 236. In that sense, there can be “only be one remedial action at a site” with 

respect to the particular contamination addressed and remedy conceived. Id.

When, as in NYSEG, the contamination to be addressed arises from a single 

source, and the operator undertakes to remedy that “underlying source of []

contamination,” 766 F.3d at 233 (citation omitted), the distinct steps taken in 

furtherance of that objective will constitute a single remediation. But a 

subsequent remediation, undertaken to address a different source of 
63

contamination outside the scope of the prior remediation, may constitute a 

separate and distinct remediation for statute of limitations purposes.

This interpretation comports more closely to the language and structure 

of the statute. CERCLA defines a “remedial action” as “those actions consistent 

with [a] permanent remedy . . . in the event of a release or threatened release of a 

hazardous substance into the environment.” 42 U.S.C. § 9601(24). This language 

indicates that the term “remedial action” refers not to any remedial activity 

undertaken on a particular site, but instead to remedial steps intended to deal 

with a particular “release or threatened release of a hazardous substance.” Id; 

see also S. Rep. No. 96–848 at 54 (July 11, 1980) (“Remedial action may be taken 

in response to a discharge, release, or a significant threat of discharge[,] release, 

or disposal of a hazardous substance.”). 

CERCLA’s implementing regulations confirm this understanding: 

typically, remediations are only undertaken after a lengthy process of data 

collection, the goal of which is to produce a comprehensive description of the 

“history/nature of waste handling” at the site and a “description of known 

contaminants.” See 40 C.F.R. § 300.420(c); id. 300.430(b). After the operator and 

the regulator obtain a comprehensive view of the “scope and complexity of the 
64

site problems being addressed,” id. § 300.430(a)(1)(ii)(C), the parties analyze 

alternative courses of action, conduct feasibility studies, and select a remedy. 

See generally id. § 300.430. It follows that the remediation that emerges from this 

process, while designed to be a “final, once-and-for-all cleanup of a site,” 

NYSEG, 766 F.3d at 236, is necessarily limited in scope to those problems 

revealed during the remedial investigation. A subsequent remediation that 

seeks to address a different set of problems — e.g. problems that were nonexistent, unknown, elsewhere, or undisclosed to the regulators and unrevealed 

in an earlier remediation plan — should not be considered part of the same 

remediation.41

In deciding whether to characterize a later remedial activity, for statute 

of limitations purposes, as a continuation of previously conducted 

41 An explicit statement in NYSEG tends to confirm that the opinion did not intend its 

generalization to apply to the circumstances outlined above. The opinion conceived the 

single-remediation principle as designed to serve logic and fairness. Its statement that “it 

would not be logical — or fair — to subject [a potentially responsible party] to additional 

CERCLA lawsuits seeking yet additional permanent relief” after that potentially responsible 

party has already completed a remediation, 766 F.3d at 236, makes good sense when applied 

in the circumstances of NYSEG and the cases cited in that opinion. But in the different 

circumstances described above in this opinion, it would be the application of the singleremediation principle that would cause unfairness. The fact that NYSEG saw the idea as one 

serving fairness reinforces the suggestion that NYSEG did not intend its application in 

circumstances where, rather than protect against unfairness, it would cause unfairness. 
65

remediation, or as a separate and distinct remediation entitled to a new sixyear period for cost recovery, a helpful inquiry would be to examine whether 

the recent action (sought by the remediator to be characterized as a new 

remediation) falls within the remedial scope of the previous remediation as 

revealed in the record before the regulatory agency. In many cases, the record 

of the correspondence between the regulatory agencies and the original 

remediators will reveal much about the nature and scope of the problem to be 

remediated as it was initially conceived. See 40 C.F.R. § 300.430(f)(5)(i) (“To 

support the selection of a remedial action, all facts, analyses of facts, and sitespecific policy determinations considered in the course of carrying out 

activities in this section shall be documented, as appropriate, in a record of 

decision . . . .”). CERCLA and its implementing regulations make clear that 

remediation requires “characteriz[ing] the nature of and threat posed by the 

hazardous substances,” including the “general characteristics of the waste, 

including quantities, state, concentration, toxicity, propensity to 

bioaccumulate, persistence, and mobility,” in addition to analyzing various site 

characteristics, to “conduct a site-specific baseline risk assessment.” Id.

§ 300.430(d)(2), 300.430(d)(4). An assessment of the documentary record 
66

associated with the prior remediation will often show whether subsequent

action is a continuation of it or distinct in its remedial purpose and scope.

When, for example, the record reveals that the more recent remediation 

addresses a different problem than the previous remediation, e.g., a “release or 

threatened release of a hazardous substance” that was unrecognized or had not 

even occurred at the time of the previous remedial activity, that would suggest 

that the recent remediation should be treated as a new and distinct remediation

for statute of limitations purposes.42 On the other hand, the more the agency 

record shows that the recent remedial activity seeks to bring about essentially 

the same “permanent remedy” of the same problem as was the goal of the prior 

remediation, the more appropriate to consider the recent remediation as a 

continuation of the prior remediation. NYSEG, 766 F.3d at 235. (As we 

recognized in NYSEG, the possibility that technological advancement may 

42 See, e.g., Valbruna Slater Steel Corp. v. Joslyn Mfg. Co., No. 1:10-cv-044, 2013 WL 1182985, at 

*12 (N.D. Ind. Mar. 21, 2013) (finding that a recent remedial action was “distinct from the 

remedial project undertaken by [a previous owner] over the last decade” because the previous 

project “dealt primarily with RCRA compliance in two small areas that comprised only a 

fraction of the whole Site, not with overall CERCLA compliance at the whole Site, as the 

current remedial plan does,” and were carried out “before the current Site-wide remedial 

action was even found to be necessary”).
67

reveal new methods of remediating a particular contamination problem would 

not necessarily create the opportunity to pursue such methods as a distinct 

“remedial action,” particularly if those methods undertake to solve the same 

problems already addressed by the prior remediation. NYSEG, 766 F.3d at 236 

(“[W]e recognize that what seems final at a given point in time might come to 

appear inadequate at a later date as scientific knowledge progresses.”).)

We conclude that the district court’s reliance on the single-remediation 

principle asserted in NYSEG did not necessarily support its conclusion that 

MPM’s cost recovery action was untimely. We vacate the judgment and 

remand for further consideration. Consistent with our discussion above, the 

district court’s analysis on remand should address whether MPM’s remedial 

activity addressed to buried PCBs is part of the remediation begun by UCC in 

the 1990s, such that the instant suit filed in 2011 is untimtely, or should be 

deemed a separate and distinct remediation, entitled to a new six-year 

limitation period. 

ii. Future Removal Costs

With respect to removal costs MPM may incur in the future, UCC 

challenges the district court’s declaratory judgment that UCC is liable for at 
68

least a share, as well as its allocation of 95% of those costs against UCC. UCC 

argues first that the possibility of future removal costs is too remote to present 

a constitutionally ripe controversy as to its liability for those costs, UCC Br. at 

44–48; second, that the circumstances are “too speculative” to present a ripe 

controversy over the allocation of future costs, id. at 48–55; and, third, that cost 

allocation is not “prudentially ripe” because the issue would “benefit from [] 

further factual development” and because “[d]eferring allocation of 

hypothetical future removal costs would impose no real hardship on MPM,” 

id. at 55–56 (citation omitted).43 We disagree.

43 UCC further argues that, while § 113(g)(2) of CERCLA does require a court to issue “a 

declaratory judgment on liability for response costs,” the statute does not require a 

declaration of “future allocation when a party is found liable for past response costs.” UCC

Br. at 57. UCC further argues that the district court’s decision to issue such a declaration was 

an abuse of discretion under the Declaratory Judgment Act because that declaration neither 

“serve[s] a useful purpose” nor would it “finalize the controversy and offer relief from 

uncertainty.” Id. (quoting Dow Jones & Co. v. Harrods Ltd., 346 F.3d 357, 359 (2d Cir. 2003)). For 

the reasons stated in this subsection, we reject UCC’s argument.

Moreover, UCC argues that the district court abused its discretion by failing to include in its 

declaratory judgment a contingency provision which would authorize the parties to relitigate 

the allocation if “new facts or future events render the current division inequitable,” citing to 

the Third Circuit’s decision in Beazer East, Inc. v. Mead Corp., 412 F.3d 429, 449 (3d Cir. 2005) 

(noting that “[s]uch contingency provisions are generally favored in CERCLA contribution 

actions”). UCC Br. at 57–58. MPM points out, MPM Reply Br. at 39–40, that the Third Circuit 

held that such a provision would be appropriate in Beazer because, in that case, both the 

plaintiff and the defendant were potentially responsible for the contamination, and that the 

district court’s “allocation would no longer be fair if any required remediation is primarily or 
69

a. Constitutional ripeness

First, we find neither error nor abuse of discretion in the district court’s 

conclusion that the liability and allocation issues were constitutionally ripe for 

review due to the very high likelihood that MPM will incur future response 

costs. MPM III, 2017 WL 6408611, at *16–17. The doctrine of constitutional 

ripeness is “drawn from Article III limitations on judicial power” and 

“prevents a federal court from entangling itself in abstract disagreements over 

matters that are premature for review because the injury is merely speculative 

and may never occur.” In re Methyl Tertiary Butyl Ether (MTBE) Prods. Liability 

Litig, 725 F.3d 65, 110 (2d Cir. 2013) (citations omitted).44 There is no merit to 

UCC’s contention that it is speculative whether MPM will incur costs to deal 

with the PCB contamination it has uncovered at the Site. To the contrary, it is 

exclusively directed to those areas of the Site where [the plaintiff] is responsible for the 

majority of the contamination.” Beazer, 412 F.3d at 449 (quotation marks omitted). We agree 

that Beazer involved drastically different circumstances and that here, because UCC is the 

only party responsible for PCB contamination at the Site, and because no future developments 

will alter that fact, the district court did not abuse its discretion by failing to include such a 

contingency provision. But see infra at 80–81.

44 A request for a declaratory judgment is constitutionally ripe for review when “there is a 

substantial controversy, between parties having adverse legal interests, of sufficient 

immediacy and reality.” Duane Reade, Inc. v. St. Paul Fire & Marine Ins. Co., 411 F.3d 384, 388 

(2d Cir. 2005) (quoting Md. Cas. Co. v. Pac. Coal & Oil Co., 312 U.S. 270, 273 (1941)).
70

undisputed that MPM plans to continue with its wastewater treatment facility 

upgrade, which will “require that MPM respond appropriately to PCBs in the 

soils” in that area. MPM III, 2017 WL 6408611, at *17.45 MPM submitted a plan 

for PCB management during its wastewater treatment upgrade, which 

anticipates the necessity of the disposal of contaminated soil, along with other 

measures intended to “minimize the risk of spreading contamination,” and the 

WVDEP has approved that plan. There is a substantial likelihood that, 

depending on how these plans progress, at least some actions MPM will 

undertake to deal with UCC’s contamination of the Site — the extent of which 

is currently “unknown” — will be “clean-up measures taken in response to 

immediate threats to public health and safety,” which are properly 

characterized as removals. NYSEG, 766 F.3d at 230–31. 46 Accordingly, we 

45 That neither WVDEP nor the EPA have yet required MPM to undertake any response 

project in response to its discovery of PCB-contaminated soil at the site does not make the 

possibility of MPM’s expenditure of future costs speculative. See Cadillac Fairview/California v. 

Dow Chemical Co., 840 F.2d 691, 696 (9th Cir. 1988) (“The absence of a government enforcement 

action under CERCLA does not render the controversy between the party seeking declaratory 

relief and the party who owned the site at the time of the hazardous waste disposal remote 

and hypothetical.”).

46 UCC also argued that MPM’s only concrete plan for future response activity at the site — a 

soil management plan regarding the “proper handling, characterization and disposal of 

potentially impacted soil” in work areas around the wastewater treatment unit — would be 
71

conclude that the district court did not exceed its Article III jurisdiction in 

adjudicating UCC’s liability for the future removal costs that MPM is likely to 

incur. See Kelley v. E.I. DuPont du Nemours and Co., 17 F.3d 836, 844–45 (6th Cir. 

1994) (rejecting the argument that the district court’s declaration of future 

liability for cleanup costs was improper because “the wide-ranging 

contamination [at the relevant site] makes it more certain than speculative that 

the [claimant] will have to expend resources in the future”). 47

b. Prudential ripeness

a remediation (not a removal), and that the likelihood of MPM undertaking that remediation 

is irrelevant to the question whether MPM was likely to incur future removal costs. We 

disagree, in part because (as expressed above) the circumstances indicate a substantial 

likelihood that MPM will incur removal costs in the future. Additionally, we agree with 

MPM’s argument that it should not be required to prove definitively, at this stage in the 

litigation, that the future costs it will likely incur would necessarily be characterized as 

removals in order to establish that its demand for a declaratory judgment as to UCC’s liability 

for future removal costs is ripe. MPM Reply Br. at 30–31. As noted above, the classification of 

an action as a removal or a remediation is subtle and fact-intensive; requiring a plaintiff 

contemplating future response action to prove definitively that such action will be in the 

nature of removal rather than remediation in order to invoke the court’s subject matter 

jurisdiction would be inconsistent with governing precedent that a “risk of real harm” is 

sufficient to invoke a federal court’s subject matter jurisdiction. See Spokeo, Inc. v. Robins, 136 

S. Ct. 1540, 1549 (2016).

47 In support of its argument, UCC argues that “[t]o establish a constitutionally ripe 

controversy . . . MPM [] must show that its future removal costs are certainly impending,” citing 

to the Supreme Court’s decision in Clapper v. Amnesty International USA, 568 U.S. 398, 409–10

(2013). UCC Br. at 45–47 (emphasis added). This is a misreading of Clapper. The Supreme 

Court in that case — and in future rulings — clarified that a “substantial risk” of harm will 

suffice to meet Article III’s case or controversy requirements. Clapper, 568 U.S. at 414 n.5; see 

also Susan B. Anthony List v. Driehaus, 573 U.S. 149, 158 (2014).
72

The district court also correctly concluded that the issue of UCC’s 

liability and responsibility for MPM’s future response costs was prudentially

ripe. The doctrine of prudential ripeness requires a court to ask “whether the 

claim is fit for judicial resolution” and “whether and to what extent the parties 

will endure hardship if decision is withheld,” and permits a court to decline to 

exercise its jurisdiction upon determining that “the case will be better decided 

later.” MTBE, 725 F.3d at 110 (brackets and citations omitted). The district court 

determined that the issue was fit for judicial resolution because the evidence 

necessary to determine UCC’s responsibility for MPM’s future response costs 

was “before the Court and unlikely to change.” MPM III, 2017 WL 6408611, at 

*18. In particular, the court noted that “the two factors that weigh most heavily 

in [its] allocation of responsibility in this case — UCC’s status as the sole entity 

responsible for using and disposing of PCBs at the Site and MPM’s delay in 

reporting its discovery of PCBs to environmental regulators — are settled.” Id.

Further, the district court determined that it would be “unjust” to “require 

MPM to wait for allocation until MPM has ascertained [the extent of its] future 

PCB response costs,” given the “considerable” cost and time the parties had 

spent litigating this case, and that determining the parties’ respective financial 
73

responsibility for future cleanup costs without delay — as CERCLA requires 

— would “advance CERCLA’s ‘dual goals of cleaning up hazardous waste and 

holding polluters responsible for their actions.’” Id. (quoting NYSEG, 766 F.3d 

at 220).

UCC argues that the issue is not fit for resolution because “many facts 

relevant to the parties’ relative responsibility for future removal costs are 

inherently unknowable and subject to substantial uncertainty” as “many of the 

circumstances of a future cleanup are unknown.” UCC Br. at 49–51.48 UCC 

further points to several specific uncertainties which, in its view, should 

preclude a determination of cost allocation, including (a) the “extent or impact” 

48 UCC contends that, in New York v. Solvent Chemical Co., 664 F.3d 22 (2d Cir. 2011), we held 

that “when a cleanup is in progress, allocation should be deferred until ‘the uncertainties 

regarding ongoing response costs have been resolved.” UCC Br. at 49–50 (quoting Solvent 

Chemical, 664 F.3d at 27). UCC’s argument mischaracterizes our holding. In that case, the 

district court had declined to issue a declaratory judgment as to the parties’ respective liability 

for future response costs “chiefly because the allocation of future costs would be premature.” 

Solvent Chemical, 664 F.3d at 24 (emphasis in original); see also New York v. Solvent Chemical Co., 

Inc., 685 F. Supp. 2d 357, 455–56 (W.D.N.Y. 2010) (declining to allocate future costs for lack of 

sufficient data, and because regulators were “still considering alternative remedial 

proposals”). This court reversed in part, holding that the district court abused its discretion 

by declining to issue a declaratory judgment as to liability, but did not require the district 

court to issue a cost allocation order. 664 F.3d at 26. That holding does not in any way establish 

that the court may not issue a cost allocation order “when a cleanup is in progress,” UCC Br. 

at 49–50, particularly when the district court is satisfied that all the evidence required to issue 

such an order is before the court and “unlikely to change.” MPM III, 2017 WL 6408611, at *18.
74

of MPM’s delay in addressing the PCB contamination, (b) the extent of MPM’s 

future cooperation with regulators, (c) the extent to which MPM will benefit 

economically from its future cleanup efforts, (d) the extent to which MPM is 

and will be responsible for “secondary disposal” of excavated contaminated 

material at the site, and (e) whether OSi/Crompton will indemnify MPM for 

any of its future response costs. UCC Br. at 51–54. UCC further asserts that 

MPM’s “future removal actions [] may well never occur,” arguing that 

resolution of its responsibility should wait “at least until (if ever) a concrete 

plan exists to conduct a removal action and more is known about the attendant 

circumstances.” Id. at 56.

We are not persuaded. CERCLA provides a district court tasked with 

allocating responsibility for cleanup costs between potential responsible 

parties with “broad discretion to balance the equities in the interests of justice,” 

and “does not limit courts to any particular list of factors” to consider when 

making that determination. Bedford Affiliates v. Sills, 156 F.3d 416, 429 (2d Cir. 

1998), overruled on other grounds by W.R. Grace, 559 F.3d at 89–90. The district 

court was clear that the two factors on which it primarily relied were (a) UCC’s 

sole responsibility for the PCB contamination at the Site, and (b) MPM’s delay 
75

in cooperating with regulators after its discovery of PCB-contaminated soil. 

MPM III, 2017 WL 6408611, at *18. The district court found that the evidence 

supporting these two determinative factors was “unlikely to change.” Id. The 

district court had a sound basis for concluding that UCC’s insistence on 

uncertainties was exaggerated and did not call for delay in adjudicating 

allocation. Id. 49

As to the “hardship” element of prudential ripeness, MTBE, 725 F.3d at 

110 (instructing courts to determine “whether and to what extent the parties 

will endure hardship if decision is withheld”), UCC argues that “[d]eferring 

allocation of hypothetical future removal costs would impose no real hardship 

on MPM” because “[i]f MPM ever does develop a concrete plan beyond [its Soil 

Management Plan], it can seek an allocation then.” UCC Br. at 56–57. This 

49 For this reason, cases like Port of Portland v. Union Pacific Railroad. Co., No. 98-cv-886, 2001 

WL 36135190 (D. Or. Mar. 26, 2001) and Georgia-Pacific Consumer Products. LP v. NCR Corp., 

358 F. Supp. 3d 613 (W.D. Mich. 2018), in which courts have declined to allocate costs due to 

the inadequacy of the factual record to make that determination, have no bearing on this case. 

See Georgia-Pacific, 358 F. Supp. 3d at 645 (declining to issue a declaration of financial 

responsibility for future cleanup costs where there were four potentially liable parties, each 

of whom contributed to pollution in different areas, because “[t]here is a high level of 

uncertainty as to the shape of what remedies will actually apply, and no real basis to assess 

costs”); Union Pac., 2001 WL 36135190, at *10 (declining to issue declaratory relief as to cost 

responsibility because of the “site’s long history and many possible sources of contamination” 

at the site).
76

argument does not answer the district court’s determination that delaying 

determination of the allocation issue “until after MPM is again engaged in PCB 

cleanup” would be “unjust” and “wasteful” because of the “considerable” cost 

and time that have been spent in litigating the case. MPM III, 2017 WL 6408611, 

at *18 (“Determining allocation will save the litigants in this case substantial 

time and money . . . .”). Moreover, UCC does not challenge the district court’s 

determination that finalizing the issue of cost allocation — which, in its sensible 

view, it was fully capable of doing after the evidence presented at trial —

would advance CERCLA’s ultimate goals. Id.50

As the district court pointed out, its declaration of liability for and 

allocation of MPM’s future response costs does not directly establish any 

50 CERCLA requires the court to “enter a declaratory judgment on liability for response costs 

or damages that will be binding on any subsequent action or actions.” 42 U.S.C. § 9613(g)(2); 

see also Solvent Chemical, 664 F.3d at 25 (noting that CERCLA requires “a declaratory judgment 

award dividing future response costs among responsible parties” (quoting Goodrich Corp. v. 

Town of Middlebury, 311 F.3d 154, 175 (2d Cir. 2002)); see also Dent v. Beazer Materials & Servs., 

Inc., 156 F.3d 523, 531–32 (4th Cir. 1998) (“Even if multiple response costs actions exist or 

might exist, the court in the first action to reach decision [in liability] is required to enter 

judgment as to liability for the site.” (citing 42 U.S.C. § 9313(g)(2))). This requirement 

“ensure[s] that a responsible party’s liability, once established, [will] not have to be 

relitigated.” New York v. Green, 420 F.3d 99, 111 (2d Cir. 2005) (citation omitted). Moreover, 

we have said that “[t]he fact that future costs are somewhat speculative is no bar to a present 

declaration of liability.” Id. (citation omitted). 
77

financial liability. The court’s order “[left] open [] the issue of whether any costs 

MPM incurs in responding to PCBs are recoverable under CERCLA,” so that

“if and when MPM brings an action to recover future removal costs, UCC will 

be entitled to raise appropriate objections.” MPM III, 2017 WL 6408611, at *18.51

What the district court’s order did finalize was that, by reason of UCC’s sole 

responsibility for the substantial levels of PCB contamination at the Site, it is 

responsible (notwithstanding MPM’s delay) for 95% of the cost of any 

appropriate, CERCLA-compliant removals designed to address that 

contamination. As explained below, that conclusion was well supported by the 

record, and the district court was under no obligation to delay decision and 

require the parties to come back to court at some future date to litigate the 

allocation of financial responsibility for UCC’s pollution.

c. Future removal cost allocation

51 See also Green, 420 F.3d at 111 (noting that a party may raise objections to an action seeking 

recovery of CERCLA costs under a previously-issued declaratory judgment, including 

objections on the basis that the costs incurred were “inconsistent with the national 

contingency plan” or that the claimed costs were not actually incurred); Cadillac Fairview, 840 

F.2d at 695 (rejecting the argument that a declaration of liability for future costs would require 

the defendant to be “forced to pay for cleanup actions that are inadequate or ill-conceived” 

because, to recover costs under CERCLA, “the party undertaking the response action must 

prove that the costs it incurred were ‘necessary’ and that it incurred those costs in a manner 

‘consistent with the national contingency plan’” (quoting 42 U.S.C. § 9607(a)(4)(B))).
78

UCC further argues that the district court’s decision to allocate 95% of 

MPM’s future removal costs to UCC was an abuse of discretion. UCC Br. at 58–

70. The thrust of UCC’s argument is that the district court did not afford 

sufficient weight to several factors on which other courts have relied when 

making similar allocation determinations. UCC argues that the district court 

failed to take into account (a) that MPM assumed the risk of future cleanup 

costs by purchasing the Site without fully investigating potential 

contamination there, id. at 59–61, (b) that, by virtue of the documents MPM 

received before executing its purchase of the site, it was on objective notice of 

the PCB contamination, which should warrant a higher allocation to MPM 

under the doctrine of caveat emptor, id. at 62–67, and (c) the possibility that 

“future PCB cleanups . . . could result in substantial economic benefits to 

MPM,” id. at 68–69.52

52 UCC also argues that the district court did not properly consider the “timeliness of future 

removal actions, MPM’s aggravation of contamination or proximate cause of removal costs, 

and MPM’s invocation or waiver of its indemnity from Crompton,” and that the district court 

improperly disregarded its argument that MPM’s planned cleanup work under its Soil 

Management Plan is motivated by “commercial” considerations and does not aim to 

permanently cleanup PCB contamination at the site. UCC Br. at 68–70.
79

A district court’s allocation of response costs under CERCLA is reviewed 

for abuse of discretion. Goodrich Corp. v. Town of Middlebury, 311 F.3d 154, 168–

69 (2d Cir. 2002); see also United States v. Consolidation Coal Co., 345 F.3d 409, 412 

(6th Cir. 2003) (same). The allocation of CERCLA response costs is an 

“equitable determination based on the district court’s discretionary selection of 

the appropriate equitable factors in a given case.” Goodrich, 311 F.3d at 170. The

statute does not require district courts to consider or give weight to any 

particular allocation factor, but rather permits the court to determine which 

factors are most relevant to a given case. NCR Corp. v. George A. Whiting Paper 

Co., 768 F.3d 682, 700 (7th Cir. 2014) (“[W]e have stressed that the district court’s 

discretion [in allocating CERCLA costs] is broad, both when it determines how 

much weight to place on any given equitable factor before the court, and also 

when it chooses which factors are pertinent at all for the case before it.”).53

53 Courts often apply a set of factors taken from a document produced during the legislative 

debate over CERCLA, which include “the ability of the party to demonstrate that his 

contribution to the release [of a hazardous waste] can be distinguished [from the contribution 

of other parties],” “[t]he amount of hazardous waste involved,” “the degree of toxicity of 

hazardous substance involved,” “the degree of involvement of the person in the manufacture, 

treatment, transport, or disposal of the hazardous substance,” and “the degree of cooperation

between the person and the Federal, State or local government in preventing harm to public 

health or the environment.” Niagara Mohawk Power Corp. v. Chevron U.S.A., Inc., 596 F.3d 112, 
80

UCC’s argument that the district court should have assigned more weight to 

certain allocation factors is therefore unavailing. UCC does not argue that the 

district court’s cost allocation “rests on an error of law (such as application of 

the wrong legal principle) or a clearly erroneous factual finding,” and it is clear 

that the court’s decision was “within the range of permissible decisions.” 

Goodrich, 311 F.3d at 169. Accordingly, we conclude that the district court did 

not abuse its discretion in allocating 95% of MPM’s future removal costs to 

UCC. By affirming the district court’s grant of declaratory judgment on future 

removal cost allocation, we do not imply, much less rule, that the district court 

would be barred from reconsidering its allocation on the basis of new events or 

discoveries that would make the present anticipatory allocation inappropriate. 

Nor does this discussion constitute a ruling that such reconsideration of the 

130 (2d Cir. 2010) (quoting S. Rep. No. 96–848, at 345–46 (1980)). However, as stated above, 

the statute “does not limit courts to any particular list of factors, nor does the [statute] direct 

the courts to employ any particular test.” Envtl. Transp. Sys., Inc. v. ENSCO, Inc., 969 F.2d 503, 

507 (7th Cir. 1992).
81

allocation would be permitted. Our purpose is to leave the question open, 

expressing no view either way.54

C. CONCLUSION

For the foregoing reasons, we VACATE the district court’s July 7, 2016 

grant of partial summary judgment holding that MPM’s claim for recovery of 

remediation costs is time-barred under 42 U.S.C. § 9613(g)(2), AFFIRM the 

district court’s September 22, 2017 order holding that UCC is liable to MPM for 

95% of future removal costs, and REMAND for further proceedings consistent 

with this order.

54 MPM also appeals from the district court’s September 22, 2017 order on the basis that the 

district court erred in failing to allocate future remedial action costs. MPM argues that, if this 

court concludes that its claims for recovery of remedial action costs are not time-barred, it 

should direct the district court to enter a judgment allocating the costs of any future remedial 

action according to the same allocation the district court applied to future removal costs in its 

September 22, 2017 order. MPM Br. at 54. We need not consider this argument because, while 

we hold that the district court’s analysis of the statute of limitations issue was flawed, we do 

not hold that MPM’s claims are necessarily timely, but instead remand to the district court 

for further consideration of that issue consistent with this opinion.