EX-10.16



 EXHIBIT 10.16 

SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY
FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

SRV LNG CARRIER 
 TIME
CHARTERPARTY 
 Between 

SRV JOINT GAS LIMITED 
 And

 SUEZ LNG TRADING SA 

DATED 20th March 2007 

  
 Execution version – Hull No. 1688









 TABLE OF CONTENTS 

 

							
	 Clause
	  	Page No.	 
			
	 1.
	  	Definitions	  	 	1	  
			
	 2.
	  	Description and Condition of Vessel	  	 	7	  
			
	 3.
	  	Shipboard Personnel and their Duties	  	 	8	  
			
	 4.
	  	Duty to Maintain	  	 	10	  
			
	 5.
	  	Period and Trading Limits	  	 	11	  
			
	 6.
	  	Delivery and Redelivery; Extension of Charter; No Fault Termination of Charter	  	 	13	  
			
	 7.
	  	Regas Tests	  	 	20	  
			
	 8.
	  	Owner to Provide	  	 	26	  
			
	 9.
	  	Charterer to Provide	  	 	26	  
			
	 10.
	  	Building Contract	  	 	27	  
			
	 11.
	  	Hire	  	 	31	  
			
	 12.
	  	Payment of Hire	  	 	31	  
			
	 13.
	  	Space Available to Charterer	  	 	32	  
			
	 14.
	  	Miscellaneous	  	 	32	  
			
	 15.
	  	Instructions	  	 	37	  
			
	 16.
	  	Bills of Lading	  	 	37	  
			
	 17.
	  	Conduct of Vessel’s Personnel	  	 	38	  
			
	 18.
	  	Bunkers at Delivery and Redelivery	  	 	38	  
			
	 19.
	  	Stevedores, Pilots and Tugs	  	 	39	  
			
	 20.
	  	Supernumeraries	  	 	39	  
			
	 21.
	  	Assignment, Novation, Transfer and Sub-chartering / Sale of Vessel	  	 	39	  
			
	 22.
	  	Final Voyage	  	 	42	  
			
	 23.
	  	Loss of Vessel	  	 	42	  
			
	 24.
	  	Off-hire	  	 	42	  
			
	 25.
	  	Dry-docking; Time for Scheduled Maintenance	  	 	46	  
			
	 26.
	  	Ship Inspection	  	 	49	  
			
	 27.
	  	Performance	  	 	49	  
			
	 28.
	  	Salvage	  	 	55	  
			
	 29.
	  	Lien and Quiet Enjoyment	  	 	55	  
			
	 30.
	  	Exceptions	  	 	55	  
			
	 31.
	  	Injurious Cargoes	  	 	56	  


  

					
	Execution version – Hull No. 1688	 	i	 	










					
			
	 32.
	  	Grade of Bunkers	  	56
			
	 33.
	  	Disbursements	  	57
			
	 34.
	  	Laying-Up	  	57
			
	 35.
	  	Requisition	  	57
			
	 36.
	  	Outbreak of War	  	57
			
	 37.
	  	Additional War Expenses	  	57
			
	 38.
	  	War Risks	  	58
			
	 39.
	  	Both to Blame Collision Clause	  	59
			
	 40.
	  	New Jason Clause	  	59
			
	 41.
	  	Clause Paramount	  	60
			
	 42.
	  	Rules and Regulations; Trading; Pollution	  	60
			
	 43.
	  	Export Restrictions	  	62
			
	 44.
	  	Safe Navigation Clause	  	62
			
	 45.
	  	Cargo Management; Filling Level Restrictions	  	62
			
	 46.
	  	Boil-off	  	63
			
	 47.
	  	Purging and Cool Down	  	63
			
	 48.
	  	Nitrogen and Inert Gas	  	64
			
	 49.
	  	Measuring Devices	  	64
			
	 50.
	  	Sampling and Measuring of Cargo	  	64
			
	 51.
	  	Drawings, Specifications and Modifications	  	65
			
	 52.
	  	Taxes	  	65
			
	 53.
	  	Law and Arbitration	  	67
			
	 54.
	  	Construction	  	68
			
	 55.
	  	Custody Transfer and Calibration/Tank Tables	  	68
			
	 56.
	  	Drag and Alcohol Clause	  	68
			
	 57.
	  	Pollution and Emergency Response	  	69
			
	 58.
	  	ISPS Code; Maritime Transportation Security Act	  	69
			
	 59.
	  	Temperature of Tanks on Arrival at Loading Port	  	70
			
	 60.
	  	Notices	  	70
			
	 61.
	  	Non-Waiver	  	71
			
	 62.
	  	Prior Agreements	  	72
			
	 63.
	  	Consequential Damages	  	72
			
	 64.
	  	Commissions	  	72
			
	 65.
	  	Owner’s Default	  	72


  

					
	Execution version – Hull No. 1688	 	ii	 	










							
			
	 66.
	  	Specific Performance	  	 	73	  
			
	 67.
	  	Charterer’s Default	  	 	73	  
			
	 68.
	  	Liability & Indemnity	  	 	74	  
			
	 69.
	  	Corporate Guarantees	  	 	74	  
			
	 70.
	  	Confidentiality	  	 	75	  
			
	 71.
	  	Intellectual Property	  	 	75	  
			
	 72.
	  	Buoy System; Port Liability	  	 	77	  
			
	 73.
	  	Position Reporting System	  	 	77	  
			
	 74.
	  	Safety Management	  	 	77	  
			
	 75.
	  	Models	  	 	78	  
			
	 76.
	  	Conditions Precedent	  	 	78	  
			
	 77.
	  	Confirmation of Execution and Delivery	  	 	78	  


  

					
	Execution version – Hull No. 1688	 	iii	 	









 SCHEDULES 
  

			
	Schedule I	  	Main Particulars of the Vessel
	Appendix I to Schedule I	  	Vessel Performance Standards
	Schedule II	  	Building Contract Specifications
	Schedule III	  	Hire Rate and Adjustments
	Schedule IV	  	Insurance
	Schedule V	  	Letters of Indemnity
	Schedule VI	  	Form of Regas Tests Acceptance Certificate
	Schedule VII	  	Form of Consent and Agreement
	Schedule VIII	  	Form of Deed of Owner’s Guarantee
	Schedule IX	  	Form of Ownership Undertaking
	Schedule X	  	Gas Nomination Procedures
	Schedule XI	  	Notice under Clause 76


  

					
	Execution version – Hull No. 1688	 	iv	 	









 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

SRV LNG CARRIER TIME CHARTERPARTY 
 It is
this 20th day of March 2007 agreed between SRV Joint Gas Limited (hereinafter referred to as “Owner”), being the owner of a liquefied natural gas carrier to be constructed by Samsung Heavy Industries Co. Ltd. (Hull No. l688) and fitted out
as a Shuttle and Regasification Vessel (“SRV”) (hereinafter referred to as the “Vessel”), as more fully described in Clause 2, and Suez LNG Trading SA (hereinafter referred to as “Charterer”): 

RECITALS 
 WHEREAS, Charterer
intends to enter into one (1) or more LNG sale and purchase agreements which would require Charterer to provide the marine transportation of such LNG in SRVs capable of discharging regasified LNG into a subsea pipeline through an internal
turret arrangement connected to an offshore mooring buoy; 
 WHEREAS, Owner wishes to let the use and service of the Vessel to Charterer; and 

WHEREAS, in accordance with the terms and conditions hereinafter set forth, Charterer wishes to hire the use and service of the Vessel from Owner, upon
delivery of the Vessel to Owner; 
 NOW, THEREFORE, in consideration of the premises and the mutual covenants herein contained, Owner agrees to let and
Charterer agrees to hire the use and service of the Vessel in accordance with the terms and conditions hereinafter set forth: 
  

	1.	Definitions 

 For purposes of this Charter, the capitalized terms used herein shall have the meanings
ascribed to them below. 
 “***** Hour Notice” has the meaning set out in paragraph 5(a) of Schedule X. 

“Acceptance Standard” has the meaning set out in Clause 7(n). 

“Actual Discharge Rate” has the meaning set out in Clause 27(g)(ii)(2). 

“Adjusted Variable Element” has the meaning set out in paragraph 2.4(c) of Schedule III. 

“Adverse Weather Periods” has the meaning set out in Clause 27(b)(i). 

“Affiliated Company” has the meaning set out in Clause 70(d). 

“Agreed Allowance List” has the meaning set out in paragraph 2.8 of Schedule III. 

“Allowance Period” has the meaning set out in Clause 25(d). 

“Anticipated Delivery Date” has the meaning set out in Clause 6(a)(i). 

“APL” means Advanced Production and Loading AS of Vikaveien 85, N-4816, Kolbjørnsvik, Arendal, Norway; 

  

					
	Execution version – Hull No. 1688	 	1	 	









 “APL Buoy System” has the meaning set out in Clause 7(q)(iii); 

“Approved Club” has the meaning set out in paragraph 1(c)(ii) of Schedule IV. 

“Arrival” has the meaning set out in paragraph 6 of Schedule X. 

“Arriving Vessel” has the meaning set out in paragraph 3 of Schedule X. 

“Base OPEX Amount” has the meaning set out in paragraph 1.2(b) of Schedule III. 

“Blue Card” means the Civil Liability Certificate issued by the International Maritime Organisation guaranteeing that the Vessel has sufficient
insurance cover or other financial security to compensate for pollution damage in compliance with the International Convention on Civil Liability for Oil Pollution Damage (1969), as amended. 

“BOE” has the meaning set out in Clause 27(a)(ii). 

“British Thermal Unit” means the amount of heat necessary to raise the temperature of one pound of water by one degree (1°) Fahrenheit.

 “BTU/hr” means British Thermal Units per hour. 

“Builder” has the meaning set out in Clause 6(a)(ii). 

“Building Contract” has the meaning set out in Clause 6(a)(ii). 

“Builder’s Trials Expiry Date” has the meaning set out in Clause 7(a); 

“Buoy System” means two (2) buoys located in a water depth of approximately two hundred fifty (250) feet that are to be designed and
constructed by API, each having eight (8) mooring lines and anchor points, including, but not limited to, associated flexible risers and riser manifolds for connection to the flowlines, capable of accepting up to 750 mmScf per buoy from the
SRVs. 
 “Changes” has the meaning set out in Clause 42(a). 

“Changes Notice” has the meaning set out in Clause 42(a). 

“Charterer” has the meaning set out in the Preamble. 

“Charterer Affiliated Transferee” has the meaning set out in Clause 21(a)(iii). 

“Charterer’s Maximum LNG Carrier Changes” has the meaning set out in Clause 42(a). 

“Charterer’s Representatives” has the meaning set out in Clause 20, unless when used in Schedule X, when it shall have the meaning set out in
paragraph 3 of Schedule X. 
 “Charterer’s Group” has the meaning set out in Clause 68(a). 

  

					
	Execution version – Hull No. 1688	 	2	 	









 “Classification Society” has the meaning set out in Clause 2(a). 

“Code” means the United States Internal Revenue Code of 1986, as amended. 

“Commercial Operations” has the meaning set out in Schedule X. 

“Commissioning and Testing” has the meaning set out in Clause 7(a)(i). 

“Commissioning Period” has the meaning set out in Clause 7(a)(ii). 

“Compulsory Insurance” has the meaning set out in paragraph 4(a) of Schedule IV. 

“Consent and Agreement” means the agreement to be entered into in accordance with Clause 14(c) substantially in the form of Schedule VII. 

“Delivery” has the meaning set out in Clause 5(a). 

“Delivery Date” has the meaning set out in Clause 6(a)(i). 

“Deepwater Port” has the meaning set out in Clause 7(a). 

“Discharge Period” has the meaning set out in paragraph 9 of Appendix I to Schedule I. 

“Discharge Point” has the meaning set out in paragraph 11(a) of Appendix I to Schedule I. 

“Downstream Systems” means all infrastructure and systems downstream of the Buoy System’s pipeline end manifold. 

“Drydocking Allowances” means the allowance periods allocated in respect of scheduled. drydocking as set out in Clause 25(g); 

“Flag State” has the meaning set out in Clause 14(a)(i). 

“Final Trial Period” has the meaning set out in Clause 7(k). 

“First Trial Period” has the meaning set out in Clause 7(a)(ii). 

“Force Majeure” has the meaning set out in the Building Contract, unless when used in Schedule X, when it shall have the meaning set out in
paragraph 7 of Schedule X. 
 “Forward Reference Swap Rate” means the rate as defined in paragraph 1.1(b) of Schedule III. 

“Gas Day” has the meaning set out in Clause 27(g)(ii). 

“Gas Nomination Procedures” has the meaning set out in Clause 27(g)(ii). 

“Guaranteed Regas Rate” has the meaning set out in Clause 7(f). 

“GTT” means the LNG-containment system designer, GasTransport & Technigaz. 

  

					
	Execution version – Hull No. 1688	 	3	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 “HSE” has the meaning set out in Clause 74(c). 

“Hire Periods” has the meaning set out in paragraph 2.3 of Schedule III. 

“Hire Rate” has the meaning set out in paragraph 1 of Schedule III. 

“ICC” and “ICC Rules” have the meaning set out in Clause 53. 

“ISM Code” has the meaning set out in Clause 74(a)(i). 

“ISPS Code” has the meaning set out in Clause 58. 

“Initial Charter Period” has the meaning set out in Clause 5(a). 

“Insured Value” has the meaning set out in paragraph 1(a) of Schedule IV. 

“LIBOR” means the London Inter-Bank Offered Rate for United States Dollars per annum which appears on the Telerate Monitor (page 248/249 or any
replacement or such page) determined at or about 11:00 a.m. London time, as quoted on the date from which interest is accrued under this Charter for a ***** month period. 

“LNG” has the meaning set out in Clause 2(b). 

“LNG Carrier Changes” has the meaning set out in Clause 42(a). 

“Manufacturers’ Protocols” means, with respect to any Regasification Component, the scheduled maintenance protocol recommended by the Builder
and/or the manufacturer of that Regasification Component. 
 “Master Maintenance and Repair Plan” means the maintenance and repair plan (including
voyage and dry-dock maintenance and repairs) of the Vessel proposed and approved in accordance with Clause 25(f). 
 “MTSA” has the meaning set
out in Clause 58. 
 “mmscf/d” means million standard cubic feet per day. 

“No Fault Termination Date” has the meaning set out in Clause 6(r). 

“Nominated Discharge Rate” has the meaning set out in Clause 27(g)(ii). 

“Normal Performance” has the meaning set out in Clause 27(g). 

“Notice of Readiness to Discharge Gas” has the meaning set out in paragraph 7 of Schedule X. 

“Off-hire Allowance” has the meaning set out in Clause 24(h). 

“Owner” has the meaning set out in the Preamble. 

  

					
	Execution version – Hull No. 1688	 	4	 	









 “Owner Affiliated Transferee” has the meaning set out in Clause 21(b)(ii). 

“Owner’s Group” has the meaning set out in Clause 68(a). 

“Owner’s Guarantee” means the guarantee to be issued by Owner’s Guarantors in accordance with Clause 69 in the form of Schedule VIII. 

“Owner’s Guarantors” has the meaning set out in Clause 69. 

“Ownership Undertaking” means the letter of undertaking to be provided by Suez SA in the form of Schedule IX. 

“Performance Period” has the meaning set out in paragraph 7 of Appendix 1 to Schedule I. 

“Permitted Encumbrances” has the meaning set out in Clause 14(c). 

“Policy” has the meaning set out in Clause 56. 

“Primary Terminals” has the meaning set out in Clause 5(a) and “Primary Terminal” means any one of them. 

“Progress Reports” has the meaning set out in Clause 6(e). 

“Redelivery” has the meaning set out in Clause 6(q). 

“Reduced Performance” has the meaning set out in Clause 27(g)(ii). 

“Reduced Rate” means the rate of hire calculated in accordance with paragraph 4 of Schedule III. 

“Regasification Components” means all machinery and equipment on board the Vessel related to the capability of the Vessel to regasify LNG and
discharge regasified LNG, including, but not limited to, the following principal components: shell and tube vaporizers; high pressure LNG pumps; high pressure submerged turret loading swivel; and metering units. 

“Regasification Technology” means all inventions, patents, patent applications, copyrights, trade secrets, know-how and other confidential and
otherwise proprietary business and technical information associated with the design, construction and operation of the process piping, valves, controls and equipment used for the pressurization and vapourization of LNG, and includes the physical
location starting at the inlet to the LNG phase separator where entrained vapor is separated from the LNG feed to the LNG booster pumps, continuing through the booster pumps where LNG is pumped to high pressure to the LNG vapourizers that utilize a
heating medium to vaporize and superheat the LNG, and ending at the discharge of the LNG vapourizers where the high pressure gas is sent to the gas outlet piping. Regasification Technology includes all integration of controls required for operation
of vaporization but does not include: (a) the cargo transfer pumps used to transfer LNG from storage in the phase separator or (b) equipment used to supply the heating medium for the LNG vaporizers. 

“Regas Tests” has the meaning set out in Clause 7(b). 

  

					
	Execution version – Hull No. 1688	 	5	 	









 “Regas Tests Acceptance Certificate” means the certificate to be signed by the parties in accordance
with the provisions of Clause 7 in the form of Schedule VI. 
 “Regas Tests and Commissioning Procedures” has the meaning set out in Clause 7(c).

 “Reimbursable Insurances” has the meaning set out in paragraph 6 of Schedule IV. 

“Relevant Event” has the meaning set out in Clause 7(q). 

“Responsible Parties” has the meaning set out in Clause 58(a)(i). 

“Review Item” has the meaning set out in Clause 10(f). 

“Second Trial Period” has the meaning set out in Clause 7(h). 

“Specifications” has the meaning set out in Clause 2(c). 

“SRV” means the LNG shuttle and regasification vessels to be owned by Owner and that Owner will cause to be designed and constructed, and which are
capable of (i) loading LNG supply at one (1) or more locations to be designated by Charterer, (ii) off-loading vaporized LNG at the Buoy System, and/or (iii) off-loading LNG at one (1) or more locations as may be designated
by Charterer from time to time. 
 “SRV Technology” means all inventions, patents, patent applications, copyrights, trade secrets, know-how and
other confidential and otherwise proprietary business and technical information associated with the design, construction and operation of the SRV. 

“SRV Fleet” has the meaning set out in Clause 14(c)(ii). 

“SRV Operating Manual” means the operating manual detailing in a comprehensive manner the operation of the SRV and the Buoy System as proposed by
Owner and approved by appropriate government entities and Charterer in accordance with Clause 25(i). 
 “STCW” has the meaning set out in Clause
3(a)(iii). 
 “STCW Code” has the meaning set out in Clause 3(a)(iii). 

“Taxes” means any taxes, levies, imposts, duties, or withholdings imposed by any country or any political subdivision or taxing authority thereof or
therein in accordance with applicable law in force from time to time in the relevant taxing jurisdiction. 
 “Term” has the meaning set out in
Clause 5(c). 
 “Terminal” has the meaning set out in Schedule X. 

“Test Rate” has the meaning set out in Clause 7(b). 

“Third Party Transferee” has the meaning set out in Clause 21(a)(iv). 

  

					
	Execution version – Hull No. 1688	 	6	 	









 “Tripartite Agreement” has the meaning set out in Clause 6(g)(iii). 

“Unscheduled Maintenance” has the meaning set out in Clause 25(d). 

“Unscheduled Maintenance Allowance” means the allowance periods allocated in respect of Unscheduled Maintenance as set out in Clause 25(d). 

“Vessel” has the meaning set out in the Preamble. 

“Vessel on Station” has the meaning set out in paragraph 3 of Schedule X. 

Any reference to “port” shall include: (i) a port, berth dock, offshore loading facility or offshore unloading facility suitable for berthing,
loading or unloading an LNG Vessel; and (ii) the Buoy System. 
  

	2.	Description and Condition of Vessel 

 At the Delivery Date (as defined in Clause 6) of the Vessel under
and throughout the Term (as defined in Clause 5) of this Charter: 
  

	(a)	she shall be classed Det Norske Veritas (the “Classification Society”), which classification shall bear the following notations: 


1A1 Tanker for Liquefied gas, ship type 2G (Membrane tank, Maximum pressure 25 kPaG, Minimum temperature -163°C), NAUTICUS (Newbuilding)
PLUS-2, CSA-2, CLEAN, E0, F-AMC, ICS, TMON, DYNPOS-AUT, STL, BIS, NAUT-AW 
  

	(b)	she shall be in every way fit for the safe loading, discharging, handling and carrying of liquefied natural gas (“LNG”) in bulk at atmospheric pressure, the regasification of LNG, and the discharge of
regasified LNG; 

  

	(c)	she shall be constructed to the requirements listed in the vessel specifications appended to the Building Contract (the “Specifications”) and the requirements of the Vessel’s Classification Society for
vessels carrying LNG in bulk; 

  

	(d)	she shall be tight, staunch, strong, in good order and condition, and in every way fit for the service of currying and regasifying LNG and unloading LNG and regasified LNG, with her machinery, boilers, hull, cargo
installation, including gauging and other equipment suitable for measuring the level and temperature of LNG loaded on board ,the Vessel, and any other equipment (including but not limited to hull stress calculator, radar, computers and computer
systems) in a good and efficient state; 

  

	(e)	her tanks, valves and pipelines shall be liquid- and gas-tight; 

  

	(f)	she shall be in every way fitted for burning, as fuel, at sea and in port the fuels as set forth in Schedule I and capable of full operations when burning one hundred percent (100%) natural gas in lieu of fuel oil
(except for the burning of pilot fuel as specified in Schedule I); 


  

					
	Execution version – Hull No. 1688	 	7	 	










	(g)	she shall have her insulation spaces prepared as per her containment system design conditions; 

  

	(h)	she shall have on board all certificates, permits, records or other documents required by the conventions, laws, regulations or requirements referred to in Clause 2(1) below, including ISM Certification, and equipment
required from time to time by any applicable law to enable her to perform, subject to the notice provisions set out in Clause 4(a), the charter service without delay; 


 

	(i)	she shall comply with the regulations in force so as to enable her to pass through the Suez Canal to the extent such regulations permit passage by LNG coolers; 


 

	(j)	she shall comply with the description in Schedule I attached hereto; provided, however, that if there is any conflict between Schedule I and any other provision of this Charter (including Clause 2, but excluding the
Specifications which shall have a lower priority than Schedule I), such other provision of this Charter shall govern; 

  

	(k)	she shall be capable of operating with no venting of boil-off gases to the atmosphere, but shall be capable of venting if circumstances so require and if governmental authorities and other authority and safety of the
Vessel so permit; and 

  

	(l)	she shall be in full compliance with all applicable international conventions, safety and security standards, applicable permits, laws, regulations, and/or other requirements of the country of her registry, her Flag
State (as defined in Clause 14), and any other country, port or place to which she may be ordered hereunder, and all applicable regulations and/or requirements of any terminals or facilities in such ports or places where she may load or discharge in
accordance with Schedule I, Appendix 1, paragraph 1. 

  

	3.	Shipboard Personnel and their Duties 

  

	(a)	At the Delivery Date of the Vessel under and throughout the Term of this Charter: 

  

	 	(i)	she shall have a full and efficient complement of master, officers and crew for a vessel of her type, who shall in any event be not less than the number required by the laws of the Flag State and who shall be trained to
operate the Vessel and her equipment competently and safely with the ability, experience, licenses and training commensurate with the performance of their duties in accordance with internationally accepted standards as adopted on first class LNG
carriers and, when such standards become available, on vessels with on-board regasification and as required by applicable governmental authorities and any labor organization having jurisdiction over the Vessel, her officers or crew. Furthermore,
Owner undertakes that the officers and crew of the Vessel will have sufficient training in relation to operation of an SRV in order to fully perform their duties; 


 

	 	(ii)	 all shipboard personnel shall hold valid certificates of competence in accordance with the requirements of the laws of the Vessel’s Flag State
and other certificates generally held by personnel on LNG carriers and, as applicable, when relevant standards become available, on vessels with on-board regasification operated by 




  

					
	Execution version – Hull No. 1688	 	8	 	










	 	
prudent owners. In case of change of trading pattern, Charterer will provide timely notice so as to facilitate such recertification as may be reasonably practicable; 


 

	 	(iii)	all shipboard personnel shall be trained and certified to a standard customary for first class LNG carriers and, when such standard becomes available, for vessels with on-board regasification in accordance with the
relevant provisions of the International Convention on Standards of Training, Certification and Watchkeeping for Seafarers, 1978, as amended (the “STCW”) and the code related thereto (the “STCW Code”), including any future
amendments, supplements or replacements of the STCW or the STCW Code and such personnel shall subscribe to a policy accepted by Charterer regarding the use of alcohol and drugs established pursuant to Clause 56; 


 

	 	(iv)	the master, chief engineer, all cargo engineers and all deck officers shall be required to have a good working knowledge of English and shall maintain all reports with respect to the Vessel in English. All helmsmen
shall be required to have good working knowledge of English, and there shall be on board sufficient personnel, with a good working knowledge of the English language to enable cargo operations at loading and discharging places to be carried out
efficiently and safely and to enable communications between the Vessel and those loading the Vessel or accepting discharge therefrom to be carried out quickly and efficiently. 


While at the berth of the receiving facilities and. the loading facilities the Vessel’s cargo control room shall be manned by at least
one (1) officer having a good working knowledge of the English language; and 
  

	 	(v)	the terms of employment of the Vessel’s staff and crew will always remain acceptable to the International Transport Worker’s Federation and the Vessel will at all times carry a Blue Card. 


 

	(b)	Owner guarantees that throughout the Term of this Charter the master shall with the Vessel’s officers and crew, unless otherwise ordered by Charterer: 


 

	 	(i)	prosecute all voyages with the utmost dispatch; 

  

	 	(ii)	render all customary assistance; and 

  

	 	(iii)	load and discharge cargo as rapidly as possible when required by Charterer or its agents to do so, by night or by day, but always in accordance with the laws of and subject to the capabilities of the facilities at the
place of loading or discharging (as the case may be) and in each case in accordance with any applicable laws of the Flag State. 

  

	(c)	 Owner shall appoint Höegh LNG AS as managers of the Vessel, who shall be entitled to sub-contract such management to a sub-contractor approved by
Charterer (such consent not to be unreasonably withheld, conditioned or delayed) and shall not change or replace 



  

					
	Execution version – Hull No. 1688	 	9	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
such managers except with the consent of Charterer, such consent not to be unreasonably withheld, conditioned or delayed. For purposes of this Clause 3(c), Höegh Fleet Services AS shall be a
sub-contractor approved by Charterer. 

  

	(d)	Owner shall cause such managers to manage and operate the Vessel in accordance with standards no lower than the standards generally applicable to prudent owners of first-class LNG carriers and, when such standards
become available, of vessels with on-board regasification. 

  

	(e)	If Charterer considers, on reasonable and properly documented grounds, that Owner is not complying in all material respects with its obligations under this Clause 3, then Charterer may so notify Owner in writing. If,
after the expiration of ***** days following receipt by Owner of such notice, Owner has failed to rectify such non-compliance, then Charterer shall have the right, without prejudice to its other rights hereunder, to require Owner promptly to change
the manager of the Vessel to Charterer’s reasonable satisfaction. 

  

	4.	Duty to Maintain 

  

	(a)	Throughout the Term of this Charter, Owner shall, whenever the passage of time, wear and tear or any event (whether or not coming within Clause 30) requires steps to be taken to maintain or restore the conditions
stipulated in Clauses 2 and 3(a), exercise due diligence so to maintain or restore the Vessel; provided always that Charterer shall give Owner adequate notice of the Vessel’s intended trading pattern and any change therein to enable Owner to
take any steps required by this Clause 4(a) and/or otherwise required to comply with Clause 3(a) as a result of such trading pattern or change and provided further that during periods in dry-dock pursuant to Clause 25, or in lay-up pursuant to
Clause 34 or undergoing modifications or changes pursuant to Clause 42, the standard of diligence shall be the standard ordinarily applied by prudent owners to vessels of the same type in the same circumstances. 


 

	(b)	If at any time while the Vessel is on hire under this Charter the Vessel fails to comply with the requirements of Clauses 2, 3(a), 13 or 14, then hire shall be reduced to the extent necessary to indemnify Charterer for
any costs directly incurred by Charterer as a result of such failure. If, and to the, extent that, such failure effects the time taken by the Vessel to perform any services under this Charter, hire shall be reduced by an amount equal to the value of
the time so lost, calculated at the rate of hire. Any reduction of hire under this Clause 4(b) shall be without prejudice to any other right or remedy available to Charterer, but where such reduction of hire is in respect of time lost, such time
shall be excluded from any applicable calculation under Clause 27. 

  

	(c)	If Owner is in breach of its obligation under Clause 4(a), Charterer may so notify Owner in writing; and if, after the expiry of ***** days following the receipt by Owner of any such notice, Owner has failed to
demonstrate to Charterer’s reasonable satisfaction the exercise of due diligence as required in Clause 4(a), the Vessel shall be off-hire, and no further hire payments shall be due, until Owner has so demonstrated to Charterer’s reasonable
satisfaction that Owner is exercising such due diligence. 


  

					
	Execution version – Hull No. 1688	 	10	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(d)	Owner shall advise Charterer immediately, in writing, should the Vessel fail an inspection by a governmental and/or port state authority and/or a Primary Terminal. Owner shall simultaneously advise Charterer of its
proposed course of action to remedy the defects which have caused the failure of such inspection. 

  

	(e)	If the failure of an inspection or any finding of an inspection referred to in Clause 4(d) actually prevents the Vessel from normal commercial operations, then Charterer shall have the option to place the Vessel
off-hire from the date and time that the Vessel actually becomes commercially inoperable until the date and time that the Vessel again is able to resume normal commercial operations; provided, however, that the Vessel shall not be on hire thereafter
until such time as she is in a geographical position no less favorable to Charterer than the geographical position at which she went off-hire. Notwithstanding the foregoing, any service given or distance made good by the Vessel whilst off-hire under
the provisions of this Clause 4(e) (and the cost of bunkers, diesel oil, marine gas oil and boil-off which would have been used or lost to give such service or to make good such distance while so off-hire) shall be taken into account in assessing
the amount to be deducted from hire. For the purposes of this Clause 4(e), “normal commercial operations” and “commercially operable” means that the Vessel is not or will not be prevented from entering any port to which Charterer
instructed the Vessel or, as the case may be, from loading or discharging cargo at any Primary Terminal to which Charterer instructed the Vessel, in either case by reason of a failure of an inspection or any finding by a governmental and/or port
state authority or a failure of an inspection by a Primary Terminal on the basis of a violation of the criteria set by that Primary Terminal when the Vessel was first approved under a compatibility study relative to that Primary Terminal under the
conditions of third-party usage generally applicable at that Primary Terminal (as such criteria and conditions of third-party usage may be amended from time to time). 


 

	(f)	Furthermore, if any period of off-hire under Clause 4(c) exceeds ***** consecutive days, then Charterer may, if it chooses to do so by giving written notice thereof to Owner, terminate this Charter with effect from the
date on which such notice is received by Owner or from any later date stated in such notice. 

 This Clause 4 is without prejudice to any
rights of Charterer or obligations of Owner under this Charter or otherwise (including without limitation Charterer’s rights under Clause 24). 
  

	5.	Period and Trading Limits 

  

	(a)	 Subject to Clauses 6 and 22(b), Owner agrees to let and Charterer agrees to hire the Vessel for a minimum period of about twenty (20) years
commencing on the delivery of the Vessel in accordance with Clause 6 (“Delivery”) and ending when the Vessel is redelivered to Owner in accordance with Clause 6 on the twentieth (20th) anniversary of the Delivery Date, plus or minus
sixty (60) days, at 2400 hours GMT (the “Initial Charter Period”), for the purpose of carrying LNG cargo. Charterer intends that the Vessel shall be employed primarily between the loading terminals and the discharge terminals
specified in Appendix I to Schedule I hereto (the “Primary Terminals”). Nonetheless, but subject to the following provisions, the Vessel shall trade between any other parts of the




  

					
	Execution version – Hull No. 1688	 	11	 	










	 	
world, as Charterer shall direct, but excluding countries which at any time during the currency of this Charter are sanctioned by the UN Security Council or the government of the Flag State or
countries to which it would be illegal for the Vessel to trade under laws to which Owner or the Vessel are subject, subject always to Clauses 31 and 42(d) and the limits of the current Norwegian Institute Warranties and any subsequent amendments
thereof. If Charterer directs the Vessel to any LNG loading or receiving facilities other than Class 1 Primary Terminals, Charterer shall give notice to Owner sufficiently in advance thereof so as to enable Owner to comply with health, safety,
environmental or other similar regulations applicable to such other terminals including any alteration or modification required to the Vessel to meet the interface requirements of such other terminals. Charterer shall provide to Owner all relevant
information required to meet the interface requirements of such terminals as soon as possible. All reasonable costs incurred in implementing such modifications to the Vessel (and their later removal, if required to comply with the terms of this
Charter), including the time taken to implement such modifications and to comply with such regulations, necessary to allow the Vessel to load or discharge at such other terminals, shall be for Charterer’s account and shall be reimbursed to
Owner in accordance with Schedule III. Upon completing such modifications, the terminal in respect of which such modifications are made, and/or any terminal where a compatibility study has been successfully completed in respect of the Vessel, shall
be considered a Class 1 Primary Terminal and shall be added to the list of Class 1 Primary Terminals in Appendix I to Schedule I. Charterer shall also be responsible, and shall reimburse Owner in accordance with Schedule III, for all such reasonable
costs incurred, including the necessary time taken, should the interface requirements of or the regulations applicable to the Primary Terminals be altered after the date of the Vessel’s delivery under this Charter. Charterer’s rights under
this paragraph (a) to order the Vessel to such terminals other than Primary Terminals are subject to Clause 38; provided, however, that Owner consents thereto, such consent not to be unreasonably withheld or delayed and provided farther that
Charterer pays for any insurance premium required by the Vessel’s underwriters as a consequence of such order and for the cost of procuring any documentation required to enable the Vessel to trade to or enter any jurisdiction outside such
trading limits. The Vessel is not to force ice or follow ice breakers. 

  

	(b)	 Charterer shall use due diligence to ensure that the Vessel is employed between and at safe places (which expression when used in this Charter shall
include ports, berths, wharves, docks, anchorages, submarine lines, alongside vessels or lighters and other locations including locations at sea) where she can safely lie always afloat, it being understood and agreed that Charterer does not warrant
the safety of any place to which it orders the Vessel and shall be under no liability in respect thereof except for loss or damage caused by Charterer’s failure to exercise due diligence as aforesaid. So far only as concerns matters pertaining
to the Vessel’s draft or dimensions or the physical nature or characteristics of any port or other place at which the Vessel is employed, Charterer shall be deemed to have met its obligation to exercise due diligence where LNG carriers of
similar dimensions owned or chartered by first class parties unrelated to Charterer are also being sent to the same port or place in the same general time frame. Except where insurance can be obtained in relation to such operations or unless
mutually agreed, Charterer may not require LNG ship-to-ship transfer operations for any reason other than 



  

					
	Execution version – Hull No. 1688	 	12	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
in the interests of safety of the Vessel, crew and environment but subject always to the master’s reasonable discretion that such operation is, and remains, safe. If for any reason the
Vessel’s cargo is transshipped, such ship-to-ship transfer operation shall conform to standards not less than those set out in the latest published edition of the SIGTTO Ship-to-Ship Transfer Guide (Liquefied Natural Gas), if and when adopted
and as amended from time to time, and Charterer shall reimburse Owner in accordance with Schedule III for any documented additional premiums required by the Vessel’s underwriters and/or the cost of insuring any deductible under the
Vessel’s hull policy as well as all reasonably incurred expenses in relation to any such ship-to-ship transfer operations unless such ship-to-ship transfer operation is attributable to the actual fault or privity of Owner. 


 

	(c)	For purposes of this Charter, the “Term” of this Charter shall mean the period beginning upon Delivery of the Vessel by Owner to Charterer pursuant to Clause 6(a) and ending at the Redelivery (as defined in
Clause 6) of the Vessel from Charterer to Owner pursuant to Clause 6(o) (whether at the end of the Initial Charter Period or any extension thereof) or such earlier time as this Charter is terminated in accordance with the terms hereof.


  

	6.	Delivery and Redelivery; Extension of Charter; No Fault Termination of Charter 

  

	(a)	(i) Subject to Clause 6(b) below, the Vessel shall, as and when ready at the building yard, be delivered by Owner to Charterer with successful sea trials and gas trials completed and with cargo tanks containing LNG
vapor, inert gas or fresh air, at Owner’s option, at the building yard upon dropping outbound pilot on 30 October 2009 (as that date may be postponed in accordance with this Clause 6, the “Anticipated Delivery Date”). Except as
otherwise provided in Clause 6(h), Charterer shall notify Owner not later than ***** business days after completion of sea and gas trials as to whether Charterer will accept or reject the Vessel. If Charterer notifies Owner of its rejection,
Charterer shall include in its notice the specific reasons for such rejection. If Charterer notifies Owner of its acceptance, Owner shall notify Charterer of the date and time when delivery of the Vessel will take place. Subject to Charterer’s
right, if any, to receive a refund of hire in accordance with Clause 7(o)(i); the commencement of hire shall take place upon delivery of the Vessel by Owner to Charterer, which shall be effected upon Charterer’s signature of the protocol of
delivery and acceptance immediately following Owner’s acceptance of delivery from Builder. 

 Owner shall provide to Charterer
approximate notice of the date on which the Delivery of the Vessel shall occur: 
  

	 	(1)	no later than ***** days before the Anticipated Delivery Date; 

  

	 	(2)	no later than ***** days before the Anticipated Delivery Date; and 

  

	 	(3)	no later than ***** days before the Anticipated Delivery Date. 

 Thereafter, Owner shall provide to Charterer
firm notice of the date on which the Delivery of the Vessel shall occur no later than ***** days before the Anticipated Delivery Date, and shall provide Charterer with a final confirmation of such date not later than four (4) days in advance
thereof. 

  

					
	Execution version – Hull No. 1688	 	13	 	









 If Owner fails to give notice to Charterer in accordance with the procedure set out above, then the Delivery Date
shall be the date most recently notified or such earlier date as Charterer and Owner may agree (the date of actual delivery of the Vessel to Charterer being the “Delivery Date”). 

 

	 	(ii)	Owner has executed a Building Contract (the “Building Contract”) with Samsung Heavy Industries Co., Ltd. (“Builder”) as identified under Schedule I. Acceptance of the Vessel Charterer shall not be
construed as a waiver or discharge of any of the representations, warranties or undertakings made by Owner in or with respect to this Charter. 

  

					
	(b)	  	 (i)	    	The Anticipated Delivery Date shall be postponed:

  

	 	(1)	to the date specified, if any, in change orders agreed to or requested by Charterer and agreed to by Owner and Builder or issued pursuant to Clause 10(n), which expressly authorize an extension of the time of delivery
of the Vessel by Builder; 

  

	 	(2)	by the period of delay caused by Builder completing modifications in compliance with changes in the rules of the Classification Society or other statutory or regulatory bodies, to the extent that such delay
(i) entities the Builder to an extension of the delivery date under the Building Contract and (ii) was not caused, in whole or in part, by Owner’s failure to make a timely decision as to modifications affecting the Vessel, provided
that if Owner’s failure to make a timely decision is due in whole or in part to Charterer’s failure to timely decide and/or notify Owner of its decision, then compliance with this Clause 6(b)(i)(2)(ii) shall not be required in order to
postpone delivery of the Vessel hereunder; 

  

	 	(3)	by the period of delay in construction of the Vessel due to an event of Force Majeure (as defined in the Building Contract) affecting Builder’s ability to deliver the Vessel under the Building Contract or
Owner’s ability to perform under this Charter, provided Owner has given the applicable notices to Charterer pursuant to Clause 6(b)(ii) and such delay entitles the Builder to an extension of the delivery date under the Building Contract; and


  

	 	(4)	by any period of delay in the delivery of the Vessel arising as a result of unfavorable weather conditions delaying sea trials or gas trials, but only to the extent Builder is entitled to an extension of the delivery
date under the Building Contract as a result thereof. 

  

	 	(ii)	 Delays on account of such causes as are provided for in this Clause 6(b) shall be understood to be permissible delays and are to be distinguished from
unauthorized delays for which no revisions in the Anticipated Delivery Date shall be permitted. For the avoidance of doubt, unauthorized delays for which no such revisions shall be permitted shall include, but shall not be limited to, delays caused
by Owner’s 



  

					
	Execution version – Hull No. 1688	 	14	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
failure to be present for any trials conducted by the Builder in accordance with the Building Contract and delays caused by Owner’s failure to deliver Owner’s Supplies (as defined in
the Building Contract) in a timely manner according to the Building Contract. Within ***** days after being notified of the occurrence of any event of Force Majeure suffered by Builder affecting Owner’s ability to perform under this Charter and
on account of which Builder is claiming an extension of the delivery date of the Vessel under the Building Contract, Owner shall pass on to Charterer all notices received by Owner from Builder, notifying Owner of the occurrence of such event of
Force Majeure, the date such event of Force Majeure commenced and the reasons therefor, the expected duration of such event as well as, within ***** days after being notified of the event of Force Majeure, the period by which the Anticipated
Delivery Date is postponed by reason of such delay. Owner shall use reasonable endeavors to enforce its rights in the Building Contract so as to minimize such period of delay. Owner shall give Charterer revised written notices from time to time if
and when Owner obtains material additional information from Builder regarding the event of Force Majeure. Likewise, within ***** days after becoming aware that such event has ended, Owner shall notify Charterer in writing accordingly.


  

	 	(iii)	In the event that Owner delivers the Vessel to Charterer after the Anticipated Delivery Date, as such date may be postponed pursuant to sub-Clauses (i) and (ii) above, but without regard to any revision to the
Anticipated Delivery Date pursuant to Clauses 6(f) or 6(g) below, then from and including the ***** day following the Anticipated Delivery Date to and including the ***** day following the Anticipated Delivery Date, Owner shall pay Charterer *****
United States Dollars (US$*****) per day, for each full day that delivery of the Vessel is delayed. 

  

	 	(iv)	The total amount payable under this Clause 6(b) shall not, however, exceed ***** United States Dollars (US$*****) and Owner shall, upon payment thereof to Charterer, have no further liability on account of the delay in
delivery under this Charter. 

  

	(c)	If, on account of non-permissible delay, Owner fails to deliver the Vessel within ***** days of the original Anticipated Delivery Date, as extended for reasons specified in Clause 6(b)(i)(1), (b)(i)(2), (b)(i)(3) or
(b)(i)(4) above, Charterer shall have the right to cancel this Charter. If, on account of non-permissible and permissible delay, Owner fails to deliver the Vessel within ***** days of the original Anticipated Delivery Date, as extended for reasons
specified in Clause 6(b)(i)(1) or (2) above, Charterer shall have the right to cancel this Charter. 

  

	(d)	 Charterer shall be entitled, at its option; to defer the Delivery Date (the “Deferral Option”) by a period of not more than (i) *****
days by giving to Owner written notice of such deferral at least ***** days in advance of the then scheduled Anticipated Delivery Date or (ii) ***** days by giving to Owner written notice of such deferral at least ***** days in advance of the
then scheduled Anticipated Delivery Date. Charterer’s option to defer the Delivery Date as herein provided may be exercised by Charterer at no 



  

					
	Execution version – Hull No. 1688	 	15	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
additional cost to Charterer for the first ***** days of such deferral; provided that Charterer shall pay to Owner for any period of deferral in excess of ***** days an amount per day of such
deferral, commencing with the ***** day after the then scheduled Anticipated Delivery Date, equal to the aggregate of the costs Owner is obligated to pay in respect of (i) Builder’s lay up costs accumulated until the actual delivery of the
Vessel, (ii) any foregone interest on the ***** installment of the contract price for the Vessel calculated at a rate of LIBOR + *****% and, (iii) Owner’s reasonable costs (as offset by Owner’s gains, if any), including without
limitation additional interest costs in connection with Owner’s financing of the Vessel, incremental costs, if any, and any adjustment (positive or negative) to the cost of swap for fixing the rate of interest, directly attributable to such
deferral. Any amounts payable by Charterer to Owner as a result of the exercise by Charterer of the option to defer the delivery of the Vessel under this Clause 6(d) shall be paid after Owner’s presentation to Charterer of reasonable
documentation substantiating payment of such amounts by Owner either (i) in the same manner and at the same time as the first payment of hire falling due after such presentation or (ii) by means of an adjustment to the hire rate pursuant
to paragraph 1.1(c) of Schedule M, at Charterer’s option. 

  

	(e)	Owner shall provide Charterer with monthly reports (“Progress Reports”) advising of progress on the construction of the Vessel, including all design and construction drawings related to SRV aspects of the
Vessel. The first Progress Report shall be provided within ***** month after the date of execution of this Charter. Each Progress Report shall be in writing in a form from time to time proposed by Owner and approved by Charterer, such approval not
to be unreasonably withheld, conditioned or delayed, and shall include statements of any events or circumstances which may cause the Delivery Date to be delayed and the estimated period of such delay. Owner shall also deliver to Charterer (within
***** days of Owner’s receipt thereof) copies of any reports submitted by Builder to Owner under the Building Contract. 

  

	(f)	If the circumstances that give Charterer the right to cancel this Charter under Clause 6(c) arise, Owner may, without undue delay, give written notice to Charterer requesting Charterer to elect to cancel this Charter or
not and specifying a reasonable new date as the Anticipated Delivery Date. Within ***** days after receiving such notice, Charterer shall give written notice to Owner advising Owner of Charterer’s decision. If Charterer elects to continue this
Charter, the new date so specified by Owner and agreed by Charterer shall become the new Anticipated Delivery Date. If delivery hereunder is not effected on or before such new Anticipated Delivery Date, Charterer shall again have the right to cancel
this Charter upon the terms provided in this Clause 6(f). 

  

	(g)	If Owner, pursuant to any provision under the Building Contract related to delay in delivery of the Vessel, has the right to cancel the Building Contract, Owner shall promptly so notify Charterer in writing, indicating
in such notice whether Owner desires to cancel the Building Contract and requesting Charterer to elect to cancel this Charter or not and specifying a reasonable new date as the Anticipated Delivery Date. Within ***** days after receiving such
notice, Charterer shall give written notice to Owner advising Owner of Charterer’s decision. 


  

					
	Execution version – Hull No. 1688	 	16	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	(i)	If Charterer elects to cancel this Charter, this Charter shall terminate without liability to either party. 

  

	 	(ii)	If both Charterer and Owner desire to continue this Charter, this Charter shall continue, and the new date so specified by Owner shall become the Anticipated Delivery Date. 


 

	 	(iii)	If Charterer desires to continue this Charter, but Owner desires to cancel the Building Contract, then the parties shall immediately enter into good faith negotiations for a ***** day period to revise this Chatter to
compensate Owner for additional costs that Owner will incur as a result of continuing the Building Contract under the circumstances. In the event that the parties cannot agree within such period, Owner shall offer to Charterer a novation of the
Building Contract as permitted by and contemplated in that certain agreement among Charterer, Builder and Owner, dated 7 April 2006 (the “Tripartite Agreement”), which novation shall entitle Owner to be reimbursed for any payment
(including any interest component thereof) made to Builder and all costs of supervision, supplies, financing and any other expenses reasonably incurred in connection with the Building Contract. Unless Charterer, within ***** days of receipt of
Owner’s offer, agrees to take a novation of the Building Contract, Owner may proceed to cancel the Building Contract and this Charter shall thereupon be null and void. Upon Charterer’s acceptance of such offer, the time period within which
Charterer shall effect such novation shall be governed by the Tripartite Agreement. 

  

	 	(iv)	If, following an adjustment to the Anticipated Delivery Date pursuant to Clause 6(g)(ii), delivery thereunder is subsequently delayed to the extent that Owner again has a right to cancel the Building Contract, Owner and
Charterer shall again follow the provisions of this sub-Clause (g) with respect to the exercise of such right. 

  

	(h)	If, following sea trials, Owner has the right to cancel the Building Contract by reason of the Vessel having any deficiency in speed, deadweight capacity or cargo tank capacity or having any excess in fuel consumption
or boil-off rate, Owner shall forthwith notify Charterer in writing indicating in such notice whether Owner desires to cancel the Building Contract and requesting Charterer to elect to cancel this Charter or not. Within ***** hours after receiving
such notice, Charterer shall give written notice to Owner advising Owner of Charterer’s decision. 

  

	 	(1)	 the benefit of any reduction in the purchase price of the Vessel resulting from liquidated damages for deficiency or excess under Article III of the
Building Contract will be passed directly to Charterer either (i) by way of a hire reduction of ***** United States Dollars (US$*****) per day per ***** United States Dollars (US$*****) of price reduction, or (ii) if Owner receives such
sum from Builder under the Building Contract in a lump sum, either as a lump sum payment by Owner to Charterer within ***** days of the Delivery Date or, at Charterer’s option, by way of a hire




  

					
	Execution version – Hull No. 1688	 	17	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
reduction of ***** United States Dollars (US$*****) per day per ***** United States Dollars (US$*****) of price reduction, in any such case in full satisfaction of any claims by Charterer in this
respect; and 

  

	 	(2)	the performance warranties and description of the Vessel will be adjusted pro tanto to reflect the Vessel’s actual performance, capacity or technical condition compared with the Vessels technical
specifications as warranted under the Building Contract. 

  

	(i)	If, following sea trials, the Vessel is shown to have any deficiency in speed, deadweight capacity or cargo tank capacity or to have any excess in fuel consumption or boil-off rate giving rise to a claim under the
Building Contract for liquidated damages (but not giving rise to a right on the part of Owner to cancel the Building Contract), then the benefit of any reduction in the purchase price of the Vessel resulting from liquidated damages for deficiency or
excess under Article III of the Building Contract will be passed directly to Charterer either (i) by way of a hire reduction of ***** United States Dollars (US*****) per day per ***** United States Dollars (US*****) of price reduction, or
(ii) if Owner receives such sum from Builder under the Building Contract in a lump sum, either as a lump sum payment by Owner to Charterer within ***** days of the Delivery Date or, at Charterer’s option, by way of a hire reduction of
***** United States Dollars (US$*****) per day per ***** United States Dollars (US$*****) of price reduction, in any such case in full satisfaction of any claims by Charterer in this respect and the performance warranties and description of the
Vessel will be adjusted pro tanto to reflect the Vessel’s actual performance, capacity or technical condition compared with the Vessel’s technical specifications as warranted under the Building Contract. 


 

	(j)	For the avoidance of doubt, Charterer’s right to a hire rate adjustment or a lump sum payment, as the case may be, pursuant to Clauses 6(h) or 6(i) shall be irrespective of Owner’s actual receipt of liquidated
damages or purchase price adjustments from Builder under the Building Contract. The amounts for which Owner shall be liable to Charterer for such deficiency or excess, either by way of their use in calculating a hire reduction or as a lump sum
payment, as the case may be, shall be as set forth in Article III of the Building Contract, which amounts are incorporated herein by reference. 

  

	(k)	In the event that Builder is made subject to any court order for the appointment of a liquidator, winding up or dissolution, or passes any resolution in respect thereof and is thereby in default under the Building
Contract or is otherwise in default by virtue of equivalent process or proceedings having been instituted, or if Builder commits any material breach of its obligations under the Building Contract and fails to remedy such breach within ***** days of
being notified thereof by Owner, such that Owner has the right to cancel the Building Contract, then Owner shall promptly notify Charterer in writing indicating in such notice whether Owner desires to cancel the Building Contract and requesting
Charterer to elect to cancel this Charter or not. 

  

	 	(i)	If Charterer elects to cancel this Charter it shall terminate without liability to either party. 


  

					
	Execution version – Hull No. 1688	 	18	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	(ii)	If both Charterer and Owner desire to continue this Charter it shall continue, subject to completion of the construction of the Vessel and her delivery being possible following Builder’s bankruptcy or similar event
as described in this Clause 6(k). 

  

	 	(iii)	Provided that completion of the construction of the Vessel and her delivery is possible following Builder’s bankruptcy or similar event as described in this Clause 6(k), if Charterer desires to continue this
Charter, but Owner desires to cancel the Building Contract, then the parties shall immediately enter into good faith negotiations for a *****-day period to revise this Charter to compensate Owner for additional costs that Owner will incur as a
result of continuing the Building Contract under the circumstances. In the event that the parties cannot agree within such period, Owner shall offer to Charterer a novation of the Building Contract as permitted by and contemplated in the Tripartite
Agreement (subject to the consent of any liquidator, administrator or other authorized person), which novation shall entitle Owner to be reimbursed for any payment (including any interest component thereof) made to Builder and all costs of
supervision, supplies, financing and any other expenses reasonably incurred in connection with the Building Contract. Unless Charterer, within ***** days of receipt of Owner’s offer, agrees to take a novation of the Building Contract, Owner may
proceed to cancel the Building Contract and this Charter shall thereupon be null and void. Upon Charterer’s acceptance of such offer, the time period within which Charterer shall effect such novation shall be governed by the Tripartite
Agreement. 

  

	(l)	In no event shall the Vessel perform any voyage (other than sea trials or gas trials) or take on LNG after completion of gas trials on behalf of Owner, or any other person, prior to the Delivery Date without
Charterer’s written consent. 

  

	(m)	Charterer shall have the option to extend this Charter beyond the Initial Charter Period for up to two (2) additional periods of five (5) years each. The options as to extension are to be declared by notice in
writing given by Charterer to Owner: 

  

	 	(i)	in the case of the first extension period no less than ***** days prior to the termination of the Initial Charter Period; and 

  

	 	(ii)	in the case of the second extension period, no less than ***** days prior to the termination of the first extension period. 


The Fixed Element payable during each extension period shall be an amount as calculated in accordance with paragraph 1.1(a) of Schedule III.

  

	(n)	In the event that the first option under Clause 6(m) is not declared within the applicable time period, the subsequent option is irrevocably waived. 


 

	(o)	 If Charterer elects for one (1) or more extension periods under Clause 6(m), the permitted dry-docking times and planned maintenance days set out
in Clause 25 and the performance warranties set out in Clause 27, will be revised so as to take effect from the 



  

					
	Execution version – Hull No. 1688	 	19	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
commencement of each extension period to reflect the condition and performance of the Vessel reasonably to be expected and the dry-docking and maintenance reasonably to be required, taking into
account inevitable deterioration of an LNG carrier/SRV, notwithstanding prudent operation by her owner during a 20-year period and any extension periods. In the event that Owner and Charterer are unable to agree revised figures, the issue will be
determined by arbitration as provided in Clause 53 of this Charter and the arbitrators will substitute figures determined on the basis set out above. 

  

	(p)	Subject to Clause 6(o) and the maximum number of extension periods being two (2) in any event, the terms and conditions, including paragraph 1.1 of Schedule III, of this Charter shall remain unchanged during any
extension periods, unless expressly agreed otherwise in writing. 

  

	(q)	The Vessel shall be redelivered by Charterer to Owner on dropping outward pilot at one safe LNG port at Charterer’s option with tanks under LNG vapors and heel also at Charterer’s option. Charterer shall give
Owner ***** days’ approximate and, subject to the provisions of Clauses 5 and 22(b), ***** days’ firm written notice of the date and port of redelivery (“Redelivery”). 


 

	(r)	Charterer shall have the option, at any time after Delivery hereunder, to terminate this Charter without cause by providing irrevocable notice to Owner at least ***** years in advance of Charterer’s election (the
date of such termination being the “No Fault Termination Date”). The notice of no fault termination shall not be effective prior to the expiration of ***** years from the Delivery Date so that the No Fault Termination Date may not occur
prior to the expiration of ***** years from the Delivery Date. On the No Fault Termination Date, Charterer shall pay to Owner a termination fee equal to the sum calculated in accordance with the provisions of paragraph 6 of Schedule III. Upon
Charterer’s payment of the termination fee, neither party shall have any further obligation or liability to the other under this Charter or in connection with the construction of the Vessel, provided that the provisions of Clauses 52, 53 and 68
shall survive the termination of this Charter under this Clause 6(r). The foregoing Charterer option shall be without prejudice and shall not affect any right of termination given to Charterer elsewhere in this Charter. 


 

	7.	Regas Tests 

  

	(a)	Following Delivery of the Vessel under Clause 6, the Vessel shall proceed from the building yard to the first port of loading as instructed by Charterer to load its first cargo of LNG and shall thereafter proceed with
all due dispatch to the Buoy System located at the deepwater port in Massachusetts Bay; United States of America (the “Deepwater Port”) or, subject to Clause 7(r), any alternate APL Buoy System to which Charterer instructs the Vessel:


  

	 	(i)	for completion of the commissioning of (1) the Regasification Components, conducted in accordance with the provisions for testing under Article VI of the Building Contract (“Commissioning and Testing”),
(2) the Buoy System and (3) the Downstream Systems; 


  

					
	Execution version – Hull No. 1688	 	20	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	(ii)	followed by a period for testing of the Regasification Components, including time taken to discharge regasified LNG following completion of such testing (the “Commissioning Period”), so that the total number
of days, including the Commissioning Period but excluding any delays under Clause 7(q)(i), shall not exceed ***** days (the “First Trial Period”). 


Owner shall procure that the Builder shall conduct the regasification trials and testing in accordance with the provisions of the Building Contract and the
Specifications. Subject always to the provisions of Clause 7(s), the Commissioning and Testing shall be conducted with all due dispatch following completion of the commissioning of the Buoy System and the Downstream Systems and a written
notification from Charterer that the Buoy System and the Downstream Systems are ready and capable to receive regasified LNG, but shall be commenced in any event not later than a date falling ***** months from the Delivery Date plus any extension of
such date as Owner may obtain under Article VI, paragraph 8.1 of the Building Contract (the “Builder’s Trials Expiry Date”). 
  

	(b)	A number of regasification trials to test the Vessel’s actual discharge capacity of regasified LNG (the “Test Rate”) shall be conducted, all in accordance with a test scope and procedures to be agreed
upon by Owner and Charterer in accordance with Clause 7(c) (the “Regas Tests”). The Regas Tests shall take place at the Deepwater Port or, subject to Clause 7(r), any alternate APL Buoy System to which Charterer instructs the Vessel.


  

	(c)	A detailed scope of, and the procedures to be followed during, Commissioning and Testing and the Regas Tests (the “Regas Tests and Commissioning Procedures”) shall be discussed and developed between Owner and
Charterer during the construction period of the Vessel contemporaneous with the discussions between Owner and the Builder in relation to the development of the scope of, and the procedures to be followed during, regasification trials to be conducted
under the Building Contract during Commissioning and Testing as referred to in Clause 7(a). The final Regas Tests and Commissioning Procedures shall be approved by Charterer and Owner not later than ***** days before the Delivery Date.


  

	(d)	The Regas Tests shall be conducted in the manner agreed pursuant to Clause 7(c) in order to establish fulfillment of the performance requirements for the Vessel in respect of the discharge of regasified LNG as set forth
in paragraph 11(a) of Appendix I to Schedule I. 

  

	(e)	 To the extent that the First Trial Period exceeds ***** consecutive days, then, subject to the provisions of Clause 7(q), the Vessel shall be
off-hire, commencing on the ***** day until such time as the Vessel arrives again at the location of its next loading, with credit for time and/or distance made good. For the avoidance of doubt, any such period of off-hire under this Clause 7(e)
shall include any period during which the Vessel is in a repair yard for rectification of a regasification deficiency, commencing with the Vessel’s departure from the Deepwater Port (or, subject to Clause 7(r), any alternate APL Buoy System to
which Charter instructs the Vessel) until the Vessel arrives at the location of its next loading, with credit for time and/or distance made good, provided that the Vessel shall not be off-hire if the time taken to discharge the first cargo exceeds
the First Trial 



  

					
	Execution version – Hull No. 1688	 	21	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
Period by reason of the Vessel operating in compliance with the requirements and procedures stipulated in the Regas Tests and Commissioning Procedures, as outlined in Clause 7(c).


  

	(f)	If, after completion of the First Trial Period in accordance with Clause 7(c), the Test Rate achieved during any one of the Regas Tests conducted during the First Trial Period is equal to or greater than 712.5 MMScf/day
(the “Guaranteed Regas Rate”), then Charterer and Owner shall sign the Regas Tests Acceptance Certificate in the form of Schedule VI and the remaining provisions of this Clause 7 shall not apply. 


 

	(g)	If, after completion of the First Trial Period in accordance with Clause 7(c), none of the Test Rates achieved during the First Trial Period is equal to or greater than the Guaranteed Regas Rate, a second set of Regas
Tests shall be conducted as soon as practicable after the discharge of the first cargo and the completion of remedial works to the Vessel, if any, and once the Vessel again arrives at the Deepwater Post (or, subject to Clause 7(r), any alternate APL
Buoy System to which Charterer instructs the Vessel with a new cargo. 

  

	(h)	The second set of Regas Tests shall take no longer than ***** consecutive days, including time taken to discharge regasified LNG following completion of such Regas Tests (the “Second Trial Period”). To the
extent that the Second Trial Period exceeds ***** consecutive days, then subject to the provisions of Clause 7(q), the Vessel shall be off-hire, commencing on the ***** day until such time as the Vessel arrives again at the location of its next
loading, with credit for time and/or distance made good. For the avoidance of doubt, such period of off-hire under this Clause 7(h) shall include any period during which the Vessel is in a repair yard for rectification of a regasification
deficiency, commencing with the Vessel’s departure from the Deepwater Port (or, subject to Clause 7(r), any alternate APL Buoy System to which Charterer instructs the Vessel) until the Vessel arrives at the location of its next loading, with
credit for time and/or distance made good. 

  

	(i)	If, after completion of the Second Trial Period in accordance with Clause 7(c), the Test Rate achieved during any one of the Regas Tests conducted during the Second Trial Period is equal to or greater than the
Guaranteed Regas Rate, then Charterer and Owner shall sign the Regas Tests Acceptance Certificate in the form of Schedule VI and the remaining provisions of this Clause 7 shall not apply. 


 

	(j)	If, after completion of the Second Trial Period in accordance with Clause 7(c), none of the Test Rates achieved during the Second Trial Period is equal to or greater than the Guaranteed Regas Rate, a third set of Regas
Tests shall be conducted as soon as practicable after discharge of the second cargo and the completion of remedial works to the Vessel, if any, and once the Vessel again arrives at the Deepwater Port (or, subject to Clause 7(r), any alternate APL
Buoy System to which Charterer instructs the Vessel) with a new cargo. 

  

	(k)	 The third set of Regas Tests shall take no longer than ***** consecutive days, including the time taken to discharge regasified LNG following
completion of the Regas Tests (the 



  

					
	Execution version – Hull No. 1688	 	22	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
“Final Trial Period”). To the extent that the Final Trial Period exceeds ***** consecutive days, then, subject to the provisions of Clause 7(q), the Vessel shall be off-hire, commencing
on the ***** day until such time as the Vessel arrives again at the location of its next loading, with credit for time and/or distance made good. For avoidance of doubt, any such period of off-hire under this Clause 7(k) shall include any period
during which the Vessel is in a repair yard for rectification of a regasification deficiency, commencing with the Vessel’s departure from the Deepwater Port (or, subject to Clause 7(r), any alternate APL Buoy System to which Charterer instructs
the Vessel) until the Vessel arrives at the location of its next loading, with credit for time and/or distance made good. 

  

	(l)	If, after completion of the Final Trial Period in accordance with Clause 7(c), the Test Rate achieved during any one of the Regas Tests conducted during the Final Trial Period is equal to or greater than the Guaranteed
Regas Rate, then Charterer and Owner shall sign the Regas Tests Acceptance Certificate in the form of Schedule VI and the remaining provisions of this Clause 7 shall not apply. 


 

	(m)	Charterer shall use reasonable efforts to co-operate with, and assist Owner in discharging any remaining cargo left on board the Vessel at the end of any of the commissioning and/or trial periods under this Clause 7 in
the most efficient way, including directing the Vessel to proceed to any other United States or Gulf of Mexico Primary Terminal to discharge the remaining cargo as LNG. 


 

	(n)	If, after the completion of Commissioning and Testing in accordance with the Building Contract and of all Regas Tests in accordance with this Clause 7, the Test Rate is equal to or greater than 500 MMScf/day (the
“Acceptance Standard”), but less than the Guaranteed Regas Rate, then Owner shall pay liquidated damages to Charterer in the amount of ***** US Dollars (US$*****) for each percentage (pro rata for any partial percentage thereof) that the
Test Rate is less than the Guaranteed Regas Rate, provided that the aggregate amount of liquidated damages payable in accordance with this Clause 7(n) shall not exceed ***** US Dollars (US$*****) (US$***** x *****%, i.e. liquidated damages in
accordance with this Clause 7(n) shall not be payable in respect of a Test Rate that is less than the Acceptance Standard). 

  

	(o)	If, after completion of the Commissioning and Testing in accordance with the Building Contract and of all Regas Tests in accordance with this Clause 7, Owner is unable to establish a Test Rate which is equal to or
greater than the Acceptance Standard, then Charterer shall have the option to either terminate this Charter or to accept the Vessel for use as an SRV with deficient regasification capacity. 


 

	 	(i)	 If Charterer elects to terminate this Charter, Owner shall reimburse Charterer for all hire paid to Owner, and not earned, from the Delivery Date to
the effective date of Charterer’s termination of the Charter, plus interest thereon at LIBOR plus *****%. For the avoidance of doubt, Charterer shall pay for the cost of any bunkers, diesel oil, marine gas oil and boil-off consumed or lost in
providing any service during such period. Furthermore, in assessing the amount of any credit given for distance made good and/or service given during any off-hire periods 



  

					
	Execution version – Hull No. 1688	 	23	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
under this Clause 7, including for the calculation of any sum, if any, due by Owner to Charterer in respect of hire paid but not earned under this Clause 7(o)(i), the cost of bunkers, diesel oil,
marine gas oil and boil-off consumed or lost in making good any distance and/or providing any service during any such off-hire periods shall also be taken into account. Following such payment, if any, Owner shall have no further liability hereunder.
Following Charterer’s election to terminate this Charter pursuant to this Clause 7(o), Charterer shall have no further liability hereunder. 

  

	 	(ii)	If Charterer elects to accept the Vessel for use as an SRV with deficient regasification capacity, then Owner’s payment of the liquidated damages set forth in Clause 7(n) shall discharge Owner’s liability to
Charterer for such deficiency and the highest Test Rate achieved during any of the Regas Tests conducted during any of the First Trial Period, the Second Trial Period or the Final Trial Period shall be the rate, subject to adjustment in accordance
with paragraph 11(b) of Appendix I to Schedule I, for purposes of measuring Owner’s ongoing performance for the duration of this Charter, including any adjustments to the Reduced Rate under paragraph 4 of Schedule III and the provisions of
Clause 27(g) to the extent necessitated the agreement reached between the parties in relation to the hire rate. In respect of the hire rate applicable to the deficient SRV, the Parties may mutually agree to an adjustment to the hire rate within
***** days from the occurrence of the deficiency; provided, however, that any discussions that the parties may have under this Clause 7(o)(ii) shall not affect Charterer’s right to terminate under Clause 7(o)(i). 


The foregoing notwithstanding, Charterer’s right to terminate this Charter under Clause 7(o)(i) above shall be subject to Owner being entitled to a
further period to repair the Vessel so as to achieve a Test Rate which is equal to or greater than the Acceptance Standard. Such final testing, as provided for in the preceding sentence, shall be conducted in accordance with Clause 7(k). The Vessel
shall be off-hire during such further period of repair. Charterer may terminate the Charter if any period during which the Vessel is off-hire during the First Trial Period, the Second Trial Period, the Final Trial Period and such further period of
repair exceeds ***** days in the aggregate. 
  

	(p)	Any amounts payable by Owner to Charterer in liquidated damages under Clause 7(n) shall be paid by Owner to Charterer within ***** days of Charterer’s demand on Owner, but in any event not later than (i) *****
days after the date of execution of the Regas Tests Acceptance Certificate or (ii) the ***** day after commencement of the Final Trial Period, whichever occurs earlier. 


 

	(q)	Notwithstanding any other provisions of this Clause 7, the Vessel shall not be off-hire nor shall Owner be liable to pay liquidated damages, to the extent the occurrence of any one or more of the Relevant Events prevent
the Vessel from completing the Regas Tests within the allocated time periods and/or from achieving the Guaranteed Regas Rate and/or the Acceptance Standard. For purposes of this Clause 7, “Relevant Events” shall mean the following:


  

	 	(i)	the Buoy System and/or the Downstream Systems not being ready or able to receive regasified LNG at a rate equal to or greater than the Guaranteed Regas Rate or at any other lower rate, if such rate is required to be
discharged under the Regas Tests and Commissioning Procedures, and/or at the pressures and the temperatures as specified in the Regas Tests and Commissioning Procedures; 


  

					
	Execution version – Hull No. 1688	 	24	 	










	 	(ii)	the relevant regulatory authorities not having given their required approvals in relation to or in connection with the Deepwater Port or the requirements of the regulatory authorities not having otherwise been satisfied
by reason other than a failure or default on the part of Owner; 

  

	 	(iii)	Charterer instructing, other than as a result of a failure or default on the part of Owner, the Vessel to proceed from the Deepwater Port to any other Primary Terminal, other than a Primary Terminal which is a third
party buoy system of compatible APL design (an “APL Buoy System”) and in respect of which the provisions of Clause 7(r) shall apply, to discharge the Vessel’s cargo in part or in full as LNG; 


 

	 	(iv)	the Vessel having to disconnect from the Buoy System and/or to depart from the Deepwater Port or being prevented from discharging her cargo as regasified LNG in order to comply with the applicable requirements and
guidelines of the Classification Society, the Vessel’s Flag State or any other relevant regulatory authority and/or with such requirements as set out in the SRV Operating Manual in relation to the Vessel’s safe operation, cargo management
and/or filling level restrictions; 

  

	 	(v)	any other events or circumstances which prevent the performance or completion of the Regas Tests, but which have not arisen due to a failure on the part of, or the fault of, Owner. 


 

	(r)	In the event that Charterer instructs the Vessel to proceed to an APL Buoy System, Charterer and Owner shall review, and revise or amend by mutual agreement: 


 

	 	(i)	the Regas Tests and Commissioning Procedures to take account of such operational parameters and environmental conditions as may be relevant to enable the Vessel to discharge regasified LNG at any such APL Buoy System
for purposes of allowing the Regas Tests under this Clause 7 to be conducted at such APL Buoy System; and 

  

	 	(ii)	to the extent necessitated by Charterer’s instruction and any revisions and amendments agreed to the Regas Tests and Commissioning Procedures, the provisions of this Clause 7; 


provided that the Vessel shall remain on-hire during such time as the mailers under paragraphs (i) and (ii) are being agreed by the
parties, and provided further that the provisions of Clause 7(s) shall apply if Regas Tests at such APL Buoy System cannot be commenced on or before the Builder’s Trials Expiry Date. 

  

					
	Execution version – Hull No. 1688	 	25	 	










	(s)	In the event that Commissioning and Testing and/or the Regas Tests cannot be commenced on or before the Builder’s Trials Expiry Date by reason of the occurrence of any one or more Relevant Events, Charterer shall
be required to accept the Vessel in the condition and with the Vessel’s capacity to discharge regasified LNG as at the Delivery Date under the Charter, and Charterer and Owner shall sign the Regas Tests Acceptance Certificate in the form of
Schedule VI, clean and free of any conditions or qualifications as to the Vessel’s capacity to discharge regasified LNG. Upon signature of the Regas Tests Acceptance Certificate, Owner shall have no further liability to Charterer under Clause 7
of the Charter in respect of the payment of liquidated damages or otherwise. Provided that in that event, the provisions of Clause 27(g) of the Charter shall continue to apply in relation to performance requirements for the Vessel in respect of the
discharge of regasified LNG during the Term of the Charter, but subject to any adjustment of Normal Performance in accordance with the provisions of paragraph 11(b) of Appendix I to Schedule I in the event that the highest actual discharge rate of
the Vessel as established during the first three (3) Discharge Periods following the date of signature of the Regas Tests Acceptance Certificate is less than Normal Performance. 


 

	8.	Owner to Provide 

 Owner undertakes to provide and, subject to the provisions of Schedule III, to pay for
all provisions, wages (including but not limited to all overtime payments, statutory or otherwise, and shipping and discharging fees and all other expenses of the master, officers and crew; also, except as provided in Clauses 5 and 37, for all
insurance on the Vessel described in Schedule IV, for all deck, cabin and engine-room stores and necessary spare parts, and for water; for all dry-docking (and gas-freeing of the Vessel associated therewith), overhaul, maintenance and repairs to the
Vessel, including maintaining and operating the Vessel in good working order in accordance with prudent industry practices and Builder’s maintenance recommendations; and for all fumigation expenses and de-rat certificates. Owner’s
obligations under this Clause 8 extend to all liabilities for customs or import duties arising at any time during the performance of this Charter in relation to the personal effects of the master, officers and crew, and in relation to the stores,
provisions and other matters aforesaid which Owner is to provide and pay for and Owner shall refund to Charterer any sums Charterer or its agents may have paid or been compelled to pay in respect of any such liability on presentation of reasonable
supporting documentation. Any amounts allowable in general average for wages and provisions and stores shall be credited to Charterer insofar as such amounts are in respect of a period when the Vessel is on-hire. 

 

	9.	Charterer to Provide 

  

	(a)	 Except as provided in Clause 9(b), Charterer shall provide and pay for all bunker fuels and marine gas oil as well as all boil-off gas if used as fuel
or burned for dumping while steaming at a reduced rate under this Charter. In addition, Charterer shall provide and pay for all boil-off used to provide power for discharge, regasification and post-Delivery Regas Tests, all LNG used during Regas
Tests (whether conducted pre-Delivery or post-Delivery), and gas oil/diesel oil for the nitrogen gas and/or inert gas and diesel generators, but excluding fuel used in connection with a general average sacrifice or expenditure. Charterer shall also
provide and pay for towage and pilotage and shall pay agency fees, port charges, commissions, expenses of loading and unloading cargoes, 



  

					
	Execution version – Hull No. 1688	 	26	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
canal dues and all charges, other than those payable by Owner in accordance with Clause 8; provided, however, that all charges for such items shall be for Owner’s account when such items are
consumed, employed or incurred for Owner’s purposes or while the Vessel is off-hire (unless such items reasonably relate to any service given or distance made good and taken into account under Clause 24 or 25) and provided further that any fuel
used in connection with a general average sacrifice or expenditure shall be paid for by Owner. 

  

	(b)	All bunkers consumed for Owner’s purposes shall be for Owner’s account and shall be deducted from hire as hire becomes due at the price paid by Charterer at the last place of supply. 


 

	10.	Building Contract 

  

	(a)	Subject to the provisions of Clause 2, Owner represents and warrants that a true and complete copy of the Building Contract has been delivered to Charterer and that the Vessel shall be constructed in accordance with the
Building Contract and in accordance with the Specifications and any other specifications, diagrams, charts, plans and drawings provided to Charterer pursuant to this Charter, which specifications, diagrams, charts, plans and drawings shall, unless
otherwise agreed by Owner and Charterer, comply with the provisions of this Charter. 

  

	(b)	If Owner proposes to make any material changes to the Building Contract or the Specifications, Owner shall provide Charterer with written notice of same specifying in such notice the nature of such changes in sufficient
detail so as to allow Charterer to make an informed decision in regard to such changes. Such detail shall, for purposes of this Clause 10(b), include any further adjustments to the Specifications or the Building Contract that such changes will
necessitate (including any estimated extension of the time for delivery of the Vessel under the Building Contract). Charterer shall have a period not exceeding ***** days within which to respond to Owner’s written notice, failing which
Charterer shall be deemed to have consented to such changes. All approvals and disapprovals under this Clause 10(b) shall rest in Charterer’s sole discretion. For purposes of this Clause 10(b), a “material change” to the Building
Contract and the Specifications is a change which: 

  

	 	(i)	could have a material effect on the performance of the Vessel with regard to the Vessel’s speed, fuel consumption, boil-off, cubic capacity and regasification performance; 


 

	 	(ii)	could have a material effect on the Anticipated Delivery Date or the amount of compensation recoverable under the Building Contract for any default on the part of the Builder; or 


 

	 	(iii)	amounts to a waiver of any material right of Owner under the Building Contract. 


Notwithstanding any other provisions elsewhere in this Charter, Charterer shall endeavour that it shall have on site at Builder’s shipyard
at all times at least one representative who is duly authorised to make any decisions on behalf of Charterer in respect of any approvals or disapprovals under this Clause 10(b). 

  

					
	Execution version – Hull No. 1688	 	27	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(c)	If Owner makes or agrees with Builder to make a material change to the Building Contract or the Specifications and such material change is not approved (or deemed approved) by Charterer as provided in Clauses 10(b) and
10(m), then Charterer, in addition to any other remedy available to Charterer hereunder or otherwise, shall have the option, on notice to Owner, to terminate this Charter. 


 

	(d)	To the extent of, and subject to, Owner’s right to pre-approve suppliers of major ship components and systems under the Building Contract, Charterer shall have the right to pre-approve all such suppliers, including
Owner-supplied items, to be used in construction of the Vessel, which approval shall not be unreasonably withheld or delayed. Owner shall not approve any such suppliers under the Building Contract without first affording Charterer the opportunity to
exercise such right. In the event that Charterer fails to provide its approval within ***** days of Owner’s notice requesting Charterer’s approval of any such suppliers, Charterer shall be deemed to have approved such suppliers.


  

	(e)	Save as already approved by Charterer at the date of execution of this Charter, Owner shall, before the same are approved by Owner for the purposes of the Building Contract, submit to Charterer prior to or during
construction of the Vessel (as appropriate and as and when received from Builder under the Building Contract), for Charterer’s approval (such approval not to be unreasonably withheld or delayed) or comment, the following: 


 

	 	(i)	The Maker’s List (as defined in the Building Contract) and Machinery and Equipment Specifications; 

  

	 	(ii)	General Arrangements with Accommodation Plan; 

  

	 	(iii)	Midship Section and Scantling Plan; 

  

	 	(iv)	Cargo Tank Arrangement and Capacity Plan; 

  

	 	(v)	Results of Model Basin Tests or of Sister-ship Sea Trials; 

  

	 	(vi)	Cargo Tank Calibration Tables and Trim and Stability Booklet; 

  

	 	(vii)	Drawing and Table of Length of Parallel Body of the Vessel; 

  

	 	(viii)	Ship-to-Shore Interface Study and Mooring Arrangement; 

  

	 	(ix)	Main Equipment List with Particulars, Machinery Arrangements and Line Diagrams of Machinery Systems; 

  

	 	(x)	Heat Balance Diagram, One Line Electrical Diagram & Electric Load Analysis, Instrumentation Systems and Emergency Shut-Down Systems; 


  

					
	Execution version – Hull No. 1688	 	28	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	(xi)	Cargo Handling Plant Operational Diagram & Calculations, Cargo Manifold Arrangement, Cargo System Diagrams and Performance Calculations, Cargo Pump Performance Curves and Cargo Compressors Performance Curves;


  

	 	(xii)	Custody Transfer Measurement Systems, Ship-to-Ship Cargo Transferor, Ballast Piping Diagram, and Coating and Painting Specifications; 


 

	 	(xiii)	Safety Plan, Fire-fighting Plan and Plan of Gas Safe / Dangerous Areas; 

  

	 	(xiv)	Depot Spare Parts; 

  

	 	(xv)	Piping of Principal Hull and Machinery Systems, including Cargo and Ballast Piping; 

  

	 	(xvi)	Control Room Layout, Cargo Handling Operational Diagram; 

  

	 	(xvii)	Hydrostatic Curves (for reference only, not for approval); 

  

	 	(xviii)	Full Information on: 

  

	 	(1)	type and accuracy of the heel and trim gauges used in calculating the Cargo Tank Calibration Tables; 

  

	 	(2)	instruments for measuring or gauging level, temperature and density of the cargo; 

  

	 	(3)	telex and other communication equipment; and 

  

	 	(4)	navigation equipment; and 

  

	 	(5)	All other plans and drawings for the Vessel and its machinery, equipment and other components received by Owner from Builder pursuant to the Building Contract and the Specifications. 


 

	(f)	Owner shall ensure that each of the above documents, calculations, and information (individually, a “Review Item”) will be true and correct as of the date of its delivery to Charterer and shall not thereafter
be materially changed without the prior consent of Charterer, such consent not to be unreasonably withheld or delayed in accordance with Clause 10(m). 

  

	(g)	Charterer shall notify Owner of Charterer’s approval or any Charterer comments or objections to any Review Item within ***** days after Charterer’s receipt of the Review Item. 


 

	(h)	If Charterer does not respond to Owner within the time period set forth in Clause 10(g) after having been presented with any Review Item, Charterer shall be deemed to have approved such Review Item. 


  

					
	Execution version – Hull No. 1688	 	29	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(i)	Within ***** days after each finalized plan, drawing or Specification has been received by Owner, and whether or not requested by Charterer, Owner shall deliver to Charterer a true copy thereof. Owner shall deliver to
Charterer, whether or not requested by Charterer, three (3) true copies of a complete set of finalised plans, drawings and Specifications for the Vessel as constructed as well as one copy of each instruction manual. The foregoing documents
shall be submitted at no cost to Charterer and shall include at least one copy of each document in electronic format. 

  

	(j)	In addition to the Progress Reports which Owner shall provide to Charterer pursuant to Clause 6(e), Owner shall, not later than ***** days following Owner’s receipt thereof from Builder, provide Charterer with true
and correct copies of all reports, documents, correspondence, proposed change orders, programs for cooldown tests, sea trials and gas trials, and other such information regarding construction, tests and trials of the Vessel and its components made
available to Owner by Builder, Builder’s subcontractors, the Vessel’s Classification Society and/or any applicable government authority (including, without limitation, copies of any such documents furnished to Owner by Builder in
conjunction with the signing of the Protocol of Delivery and Acceptance under the Building Contract) as Charterer may reasonably require to determine whether the Vessel complies at Delivery with the conditions set out in this Charter or to verify
any claims for reimbursement by Owner or any expenses payable by Charterer in accordance with the terms of this Charter). 

  

	(k)	Any monitoring carried out by Charterer pursuant to this Clause 10 shall be carried out subject to and in accordance with the provisions of Clause 14(b)(i) to 14(b)(iii). 


 

	(l)	Charterer shall notify Owner promptly in the event that it discovers any construction or materials which it believes do not conform to the requirements of the Building Contract or the Specifications. However,
Owner’s obligations under the Building Contract and this Charter shall not be affected by (i) whether or not Charterer shall have exercised any of its rights under Clause 10(k), this Clause 10(l) or Clause 14(b)(ii) any requests or
observations made or not made by Charterer’s Representatives to Owner or Owner’s representatives in connection with the exercise of such rights, or (iii) Charterer’s acts or omissions in connection with its rights under Clause
10(d) or Clause 10(e). 

  

	(m)	Without Charterer’s prior consent, which consent shall not be unreasonably withheld, conditioned or delayed, Owner shall not: 

  

	 	(i)	agree to defer the remedy of any defect or deficiency in the Vessel until after delivery of the Vessel under the Building Contract; or 


 

	 	(ii)	except for the provisions regarding Charterer’s approval of material changes to the Building Contract and the Specifications under Clause 10(b), agree to any material change related to the construction of the
Vessel, including, but not limited to any change in the Building Contract or in the Specifications, diagrams, charts, plans and drawings of the Vessel as submitted to Charterer prior to the date hereof or, any suppliers approved by Charterer in
accordance with Clause 10(d) in connection therewith. 


  

					
	Execution version – Hull No. 1688	 	30	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(n)	If Charterer reasonably requests change orders in connection with the construction of the Vessel prior to the Delivery Date, Owner shall approve and shall use reasonable endeavours to cause Builder to undertake, and to
minimize any delay resulting from, such change orders; provided that any consequential adjustment to and revisions of the guaranteed deadweight, the guaranteed cargo capacity, the guaranteed boil-off, the guaranteed speed, the guaranteed fuel
consumption, the guaranteed rate of discharge of regasified LNG or any other consequential amendments to the Specifications are agreed between Charterer and Owner before Builder undertakes such changes to the. Specifications. Owner shall not do or
fail to do, as the case may be, anything that would result in increasing any subsequent delay in Builder’s construction of the Vessel resulting from such change orders. Unless otherwise agreed, all costs incurred or savings realised by such
change orders shall be for Charterer’s account or (as the case may be) for Charterer’s benefit and the Anticipated Date of Delivery hereunder shall be postponed by the amount of the time the delivery date under the Building Contract is
delayed as a result of the change orders. Unless otherwise agreed, the Fixed Element shall be adjusted in accordance with paragraph 1.1(f) of Schedule III by the amount of all cost incurred, or (as the case may be) all savings realized, by Owner as
a result of such change orders. 

  

	11.	Hire 

 Subject as herein provided, Charterer shall pay for the use and hire of the Vessel at the rate per
day determined in accordance with Schedule III attached hereto. 
  

	12.	Payment of Hire 

  

	(a)	Subject to Clauses 4 and 24, payment of hire shall be made by wire transfer in immediately available funds to Owner’s designated bank account in New York or London in United States Dollars per calendar month in
advance, less: 

  

	 	(i)	any hire paid which Charterer reasonably estimates to relate to off-hire periods; 

  

	 	(ii)	in exceptional circumstances only, any amount disbursed by Charterer on Owner’s behalf, any advances and commissions thereon and any charges for Owner’s account pursuant to any provision of this Charter; and


  

	 	(iii)	any amounts due or reasonably estimated by Charterer to become due to Charterer under Clauses 4(b) or 27, or paragraph 5(b) of Schedule IV. 


All deductions shall be verified by Charterer by delivery to Owner of vouchers or other reasonable supporting documentation within ***** days
after the payment from which the applicable deduction is taken, failing which Charterer shall make good the applicable deduction, including interest, on the next hire payment date, without prejudice to Charterer’s rights if it is subsequently
able to verify such deduction. 
  

	(b)	 Hire shall be due on the date of Delivery of the Vessel under Clause 6(a) for the remainder of the calendar month in which Delivery takes place and
thereafter on the first day of each calendar month. Owner shall provide invoices to Charterer covering each 



  

					
	Execution version – Hull No. 1688	 	31	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
payment of hire at least ***** days before due. Charterer shall not be responsible for any delay or error by Owner’s bank in crediting Owner’s account; provided, however, that Charterer
has made proper and timely payment. If a due date for the payment of hire should fall on a day on which banks are not open for business at the place of payment, hire which would have been due shall instead be due on the next following day on which
banks are open for business at such place. Hire shall accrue on a daily basis; provided, however, that hire for any periods that constitute less than a calendar day shall be a pro rata portion of hire for such calendar day. 


 

	(c)	In default of timely payment by Charterer, 

  

	 	(i)	Owner shall notify Charterer of such default in writing and Charterer shall within ***** days of receipt of such notice pay to Owner the amount due including interest. If Charterer fails to do so, Owner may withdraw the
Vessel from the service of Charterer on no less than ***** days’ written notice, unless prior to the date of withdrawal specified in such further written notice, Charterer pays to Owner the amount due including interest. Any such withdrawal of
the Vessel from the service of Charterer shall be without prejudice to any other rights Owner may have under this Charter or otherwise; and 

  

	 	(ii)	interest on any amount due but not paid on the due date shall accrue from the day after that date up to and including the day when payment is made, at a rate per annum which shall be ***** percent (*****%) above LIBOR
on the due date, or, if no such LIBOR rate is published on that day, the LIBOR rate published on the next preceding day on which such a LIBOR rate was so published. 


 

	13.	Space Available to Charterer 

 The whole reach, burthen and decks of the Vessel and any passenger
accommodation shall be at Charterer’s disposal, reserving only proper and sufficient space for the Vessel’s master, officers, crew, or other reasonable number of personnel from Owner consistent with Charterer’s rights under Clause 20
(Supernumeraries), tackle, apparel, furniture, provisions and stores. 
  

	14.	Miscellaneous 

  

	(a)	Flag State and Vessel Name. 

  

	 	(i)	Owner undertakes that, at the Delivery Date and throughout the term of this Charter, the Vessel shall be registered under the laws of Norway on the Norwegian International Ship Register or such other country or
territory as may from time to time be established as the flag state in accordance with this Clause 14(a) (the “Flag State”) and shall in all material respects comply with regulations and requirements of the Flag State in force for vessels
registered in the Flag State. 

  

	 	(ii)	 In the event that Owner determines that it would be desirable to change the Vessel’s Flag State, Owner shall propose in writing an alternative
Flag State to Charterer for Charterer’s approval, such approval not to be unreasonably withheld, conditioned or delayed. All costs and expenses of any such proposed 



  

					
	Execution version – Hull No. 1688	 	32	 	










	 	
change shall be borne by Owner and shall include all costs and expenses attributable to such change. The foregoing notwithstanding, Charterer’s withholding of consent to Owner’s request
to change the Vessel’s Flag State to The Bahamas shall not be deemed unreasonable under any circumstances. 

  

	 	(iii)	If Charterer can reasonably demonstrate that a change of the Vessel’s Flag State would produce economic benefits and/or improve the Vessel’s status with U.S. Coast Guard, Owner shall not unreasonably withhold
the approval in response to Charterer’s request to change of Flag State, but shall use reasonable, good faith efforts to cause the Vessel to be registered as soon as reasonably practicable in the country requested by Charterer. The foregoing
notwithstanding, if such change in Flag State will require a change in the jurisdiction of incorporation of Owner and/or impact Owner’s financing arrangements in relation to the Vessel, then, provided Owner has used all reasonable endeavours,
acting in good faith, to ameliorate such impact and/or to avoid changing its jurisdiction of incorporation while accommodating such change in Flag State, Owner’s withholding of approval shall not be considered unreasonable. The cost and expense
of any such change of registry shall be borne by Charterer and shall include all reasonably incurred third-party costs and expenses attributable to or resulting from the implementation of Charterer’s request. Owner shall provide an estimate to
Charterer in advance of the amount and detail of all such costs and expenses. Owner shall use reasonable endeavours to minimize such costs and expenses. 

  

	 	(iv)	Prior to the Delivery Date, Owner shall ensure that the name of the Vessel chosen by Owner is approved by Charterer, such approval not to be unreasonably withheld, conditioned or delayed. Thereafter, no change in the
Vessel’s name shall be made by Owner without Charterer’s prior written consent, such consent not to be unreasonably withheld, conditioned or delayed. 

  

	(b)	 Inspections. Charterer or its designee shall be entitled, at Charterer’s risk and expense, from time to time within usual working hours during
construction (including dock trials, sea trials, gas trials, Regas Tests and any other tests or trials) of the Vessel, to cause its representative(s) to inspect the Vessel as they may reasonably consider necessary to ascertain whether the Vessel is
being constructed according to the Specifications. The Building Contract contains a provision giving Charterer’s representatives a continuing right to inspect and investigate the construction progress of the Vessel and the Regasification
Components with access during usual working hours to the construction and fabricating facilities of Builder and its subcontractors and Owner shall exercise reasonable efforts to enforce such right. Owner shall ensure that Charterer’s
representatives are given a continuing right to attend, and shall arrange with Builder for Charterer’s representatives to attend, all tests, inspections and trials on all major equipment and such other tests as Charterer may reasonably request
and, promptly upon Owner’s receipt thereof from Builder, Owner shall forward to Charterer the results of all such tests, trials and inspections. Subject to timely notice by Builder, Owner shall give timely written notice to Charterer of such
tests or trials. Provided that timely written notice has been given under the preceding sentence, a failure to attend such trials or tests at the time and place specified in such notice shall be deemed a waiver of the right to




  

					
	Execution version – Hull No. 1688	 	33	 	










	 	
attend such trials or tests. Any such inspection may include, without limitation, as far as is practicable, examination of the Vessel’s hull, cargo and ballast tanks, machinery, boilers,
Regasification Components, auxiliaries and equipment; review of all construction records and reports to the extent available to Owner; review of records of surveys by the Vessel’s Classification Society and relevant governmental authorities.
Any inspection carried out by Charterer under this Clause 14(b): 

  

	 	(i)	shall be made without any interference with or hindrance to the Vessel’s safe and efficient construction; 

  

	 	(ii)	shall be without prejudice to any other rights of inspection or investigation allowed to Charterer in accordance with the terms of this Charter; and 


 

	 	(iii)	shall not entitle Charterer or any of its representatives to make any request or recommendation directly to Builder or other contractor of Owner except through Owner or Owner’s representatives. 


Owner’s obligations under this Charter shall not be affected by whether Charterer shall have carried out inspections of the Vessel under
the terms hereof or by any requests or observations made to Owner or its representatives or contractors by or on behalf of Charterer during or after any such inspection. 
  

	(c)	Corporate Organization; Liens, etc. On the Delivery Date and throughout the Term, Owner represents, undertakes and warrants that: 

  

	 	(i)	Owner is and shall remain a legal entity duly organized and in good standing under the laws of its country of organization, duly qualified to do business in those jurisdictions where the nature of its activities or
property requires such qualification and authorized to own the Vessel and to perform its obligations under this Charter, and Owner has taken all necessary corporate action to authorize the execution, delivery and performance of its Obligations
hereunder; 

  

	 	(ii)	Owner is and shall remain a legal entity with no activities, assets or liabilities other than the Vessel and each of the other SRVs under charter to, or to be chartered by, Charterer from Owner (the “SRV
Fleet”) and those relating to the SRV Fleet; 

  

	 	(iii)	Owner shall maintain accurate books and records reflecting its operations separately from the books and records of any other entity and, to the extent permitted by law, shall maintain such books and records in English;


  

	 	(iv)	Owner has not and will not place, suffer to exist or permit any mortgage, lien, or encumbrance on the Vessel or the Vessel’s earnings or insurances, other than Permitted Encumbrances. Moreover, if any action is
taken to enforce any mortgage, lien, maritime claim, claim, or encumbrance on the Vessel not created or arising by, through or under Charterer (whether a Permitted Encumbrance or not), Owner shall immediately notify Charterer thereof and take such
steps as are necessary to prevent any such action from adversely affecting Charterer’s rights under this Charter; and 


  

					
	Execution version – Hull No. 1688	 	34	 	










	 	(v)	subject to Clause 21, Owner shall not change its country of organization, merge or otherwise combine with another entity or transfer its rights in the Vessel or all or substantially all of its assets to another entity
without Charterer’s prior written consent, which consent shall not be unreasonably withheld, conditioned or delayed. Each of the activities described in the preceding sentence shall be referred to as a “Reorganization.” In the event
that Owner determines it would be in the interest of Owner and not detrimental to Charterer to undertake a Reorganization, Owner shall so notify Charterer and the parties shall consult in a good faith effort to agree on the Reorganization and the
form it should take. All costs of any Reorganization shall be for the account of Owner. 

 For purposes of this Charter, “Permitted
Encumbrances” means (A) liens in favour of the crew or routine suppliers to the Vessel or liens arising by operation of law (and which if any such liens arise or be enforced, Owner shall exercise due diligence to remove),
(B) mortgages, liens, claims or encumbrances on the Vessel, her earrings or insurances, which are in effect on the Delivery Date, provided that such mortgages, liens, claims or encumbrances are the subject of a duly authorized, executed and
delivered consent and agreement substantially in form and substance as set forth in Schedule VII, as may be agreed by the parties; (C) mortgages, liens, claims or encumbrances on the Vessel, her earnings or insurances, effected subsequent to
the Delivery Date in connection with financing of the Vessel provided that the requirements in phrase (B) are met; (D) an assignment of the Building Contract to Owner’s lenders during construction of the Vessel; and (E) any other
encumbrances on the Vessel, her earnings or insurances specifically consented to in advance and in writing by Charterer. 
  

	(d)	Related Agreements and Parties. Owner represents and warrants that: 

  

	 	(i)	Owner shall have full and marketable title to the Vessel at the Delivery Date and throughout the Term; 

  

	 	(ii)	there are no encumbrances other than Permitted Encumbrances as of the date hereof; 

  

	 	(iii)	supervision contracts and management contracts shall be in effect prior to the Delivery Date as may be necessary in order for Owner to perform fully its obligations hereunder; 


 

	 	(iv)	the Owner’s Guarantors under the Owner’s Guarantee have executed and delivered the Owner’s Guarantee as a deed; 

  

	 	(v)	all of the above-referenced documents are and shall remain legal, valid and binding obligations of the parties thereto, enforceable in accordance with their respective terms, and with no defaults thereunder nor
amendments thereto having any adverse effect on Charterer’s rights hereunder; 


  

					
	Execution version – Hull No. 1688	 	35	 	










	 	(vi)	all filings, consents and approvals required for Owner to perform its obligations hereunder have been obtained and true copies thereof have been delivered to Charterer; and 


 

	 	(vii)	neither the execution, delivery nor performance of this Charter, nor the consummation of any action contemplated herein conflicts or will conflict with or results or will result in a breach of any provision of
Owner’s constitutive instruments or any law, judgment, order, decree, rule or regulation of any court, administrative agency or other instrumentality of any governmental authority or of any other agreement or instrument to which Owner is a
party or by which it or the Vessel is bound, or constitutes or will constitute a default under any provision thereof. 

  

	(e)	Charterer’s Representations and Warranties. The Charterer represents, undertakes and warrants to Owner that: 

  

	 	(i)	Charterer is and shall remain a legal entity duly organized and in good standing under the laws of its country of organization, duly qualified to do business in those jurisdictions where the nature of its activities or
property requires such qualification and authorized to charter the Vessel and to perform its obligations under this Charter, and Charterer has taken all necessary corporate action to authorize the execution, delivery and performance of its
obligations hereunder; 

  

	 	(ii)	the Ownership Undertaking has been executed concurrently herewith, in the form of Schedule IX and delivered to Owner, provided however that such Ownership, Undertaking shall be effective only upon effectiveness of this
Charter and waiver or satisfaction of all conditions precedent in Clause 76. 

  

	 	(iii)	this Charter and the Ownership Undertaking shall remain legal, valid and binding obligations of the parties thereto, enforceable in accordance with their respective terms, and with no defaults thereunder nor amendments
thereto having any adverse effect on Owner’s rights hereunder; 

  

	 	(iv)	all filings, consents and approvals required for Charterer to perform its obligations hereunder have been obtained and true copies thereof have been delivered to Owner; and 


 

	 	(v)	neither the execution, delivery nor performance of this Charter, nor the consummation of any action contemplated herein conflicts or will conflict with or results or will result in a breach of any provision of
Charterer’s constitutive instruments or any law, judgment, order, decree, rule or regulation of any court, administrative agency or other instrumentality of any governmental authority or of any other agreement or instrument to which Charterer
is a party, or constitutes or will constitute a default under any provision thereof. 

  

	(f)	 Owner’s Reporting Requirements; Charterer’s Audit Right. Commencing upon Charterer’s execution and delivery of the Regas Tests
Acceptance Certificate and continuing for the Term of this Charter, Owner shall provide Charterer with written 



  

					
	Execution version – Hull No. 1688	 	36	 	










	 	
reports, on a per-occurrence basis, detailing all incidents (other than any incidents referred to in and to be reported by Owner pursuant to Clause 74(b)) in any way involving the Regasification
Components or impacting their performance. Commencing on the first day of the month immediately succeeding the month in which Charterer executes and delivers the Regas Tests Acceptance Certificate and continuing for the Term of this Charter, Owner
shall provide to Charterer Written reports: 

  

	 	(i)	establishing compliance with Manufacturers’ Protocols, as applicable, during the preceding month; 

  

	 	(ii)	detailing the hourly performance levels actually achieved by the Regasification Components during the preceding month; and 

  

	 	(iii)	detailing compliance with all requirements contained in the licenses and/or permits issued by the relevant regulatory authorities, including, without limitation, in relation to environmental requirements.


 Charterer shall have the right from time to time during the Term of this Charter to audit all records maintained by Owner relating to the
Regasification Components for purposes of verifying the reports provided by Owner pursuant to this Clause 14(f). For purposes of such audit, Owner shall make available or shall cause to be made available to Charterer and its auditor access to such
parts of the offices of Owner as may be required to review such books and records as are relevant to the Regasification Components and their operation and maintenance during normal business hours or to the relevant records on board the Vessel at any
reasonable time to review such books and records as they relate to the Regasification Components and their operation and maintenance. Owner shall assist and cooperate with Charterer in reviewing such books and records and shall provide Charterer
with copies and explanations as may reasonably be requested for purposes of Charterer’s audit rights under this Clause 14(f). 
  

	15.	Instructions 

 Charterer shall from time to time give the master all requisite instructions and sailing
directions, and he shall keep a full and correct log of the voyage or voyages, which Charterer or its agents may inspect as required. The master shall, when requested by Charterer, furnish Charterer or its agents with a true copy of such log and
with properly completed loading and discharging post sheets and voyage reports for each voyage and other returns as Charterer may require. Charterer shall be entitled to take up to three (3) copies at Owner’s expense of any such documents
which are not provided by the master. 
  

	16.	Bills of Lading 

  

	(a)	The master (although appointed by Owner) shall be under the orders and direction of Charterer as regards employment of the Vessel, agency and other arrangements, and shall sign bills of lading and customary cargo
documents as Charterer or its agents may direct (subject always to Clauses 38(a) and 43) without prejudice to this Charter. Charterer hereby indemnifies Owner against all consequences or liabilities that may arise: 


 

	 	(i)	from signing bills of lading and cargo documents in accordance with the directions of Charterer, or its agents, to the extent that the terms of such bills of lading fail to conform to the requirements of this Charter,
or from the master otherwise complying with Charterer’s or its agents’ orders; or 

  

	 	(ii)	from any irregularities in papers supplied by Charterer or its agents. 


  

					
	Execution version – Hull No. 1688	 	37	 	










	(b)	Notwithstanding the foregoing, Owner shall not be obliged to comply with any orders from Charterer to discharge all or part of the cargo: 


 

	 	(i)	at any place other than that shown on the bill of lading; and/or 

  

	 	(ii)	without presentation of an original bill of lading; 

 unless they have received from Charterer
both written confirmation of such orders and an indemnity in a form and countersigned by a party acceptable to Owner. Owner and Charterer agree that an indemnity letter substantially in the form of Schedule V attached hereto is acceptable for
purposes of this Clause 16. 
  

	17.	Conduct of Vessel’s Personnel 

 If Charterer complains of the conduct of the master or any of the
officers or crew, Owner shall immediately investigate the complaint. If the complaint proves to be well founded, Owner shall, without delay, make a change in the appointments. Owner shall in any event communicate the result of its investigations to
Charterer as soon as possible. 
  

	18.	Bunkers at Delivery and Redelivery 

 Charterer shall accept and pay for all bunkers and marine gas oil on
board at the time of Delivery and, on Redelivery (whether it occurs at the end of the Initial Charter Period, any extension period, or on the earlier termination of this Charter), Owner shall accept and pay for all bunkers and marine gas oil
remaining on board, at the price paid at the Vessel’s last place of supply before Delivery or Redelivery, as the case may be. In addition, Charterer shall pay for any LNG heel and natural gas vapours on board at the time of Delivery at a price
equivalent to the price of propulsion fuel on board the Vessel and, on Redelivery, Owner shall pay for any LNG remaining on board, as requested by Owner, at the price of Charterer’s landed cost of LNG at the last discharge terminal called upon
by the Vessel. If bunkers are not readily available at the place of Delivery or Redelivery, Owners or Charterer, as applicable, shall deliver or redeliver the Vessel with a supply of bunkers adequate for the first voyage or for the voyage subsequent
to Redelivery as the case may be. At or about the time the Vessel conducts her gas trials or Regas Tests, Owner and Charterer shall agree on the amount of bunkers Owner shall provide, at Charterer’s expense, at Delivery. Owner shall give
Charterer the use and benefit of any fuel contracts they may have in force from time to time, if so requested by Charterer, provided that suppliers agree. 

Charterer may request Owner to arrange bankers and marine gas oil for Charterer’s account Owner shall use reasonable efforts to arrange for the most
economic prices for the same. 

  

					
	Execution version – Hull No. 1688	 	38	 	










	19.	Stevedores, Pilots and Tugs 

 Stevedores, when required, shall be employed and paid by Charterer, but
this shall not relieve Owner from responsibility at all times for proper stowage, which must be controlled by the master who shall keep a strict account of all cargo loaded, boil-off, and cargo discharged. Owner hereby indemnifies Charterer, its
servants and agents against all losses, claims, responsibilities and liabilities arising in any way whatsoever from the employment of pilots, tugboats or stevedores, who although employed by Charterer shall be deemed to be the servants of and in the
service of Owner and under its instructions (even if such pilots, tugboat personnel or stevedores are in fact the servants of Charterer, its agents or any affiliate of Charterer); provided, however, that: 

 

	 	(i)	the foregoing indemnity shall not exceed the amount to which Owner would have been entitled to limit its liability if they had themselves employed such pilots, tugboats or stevedores; and 


 

	 	(ii)	Charterer shall be liable for any damage to the Vessel caused by or arising out of the use of stevedores at discharge terminals or receiving facilities, fair wear and tear excepted, to the extent that Owner is unable by
the exercise of due diligence to obtain redress therefor from such stevedores. 

  

	20.	Supernumeraries 

 Subject to available space on-board, Charterer may place up to three
(3) representatives (“Charterer’s Representatives”) in the Vessel’s available accommodation upon any voyage or any part of a voyage made under this Charter including, for the avoidance of doubt, all regasification and
discharge operations. Owner shall supply provisions and all requisites as supplied to officers, except liquors, and Charterer shall pay the reasonable costs of such provisions or requisites for Charterer’s Representative(s) while on board the
Vessel. When accommodation is limited on board the Vessel, Charterer’s Representative(s) shall have priority over Owner’s personnel who are not officers, members of the crew, superintendents or traveling service people. Charterer’s
Representatives shall not interfere with the operation of the Vessel. 
  

	21.	Assignment, Novation, Transfer and Sub-chartering / Sale of Vessel 

  

	(a)	By Charterer 

  

	 	(i)	Charterer may sub-charter the Vessel by time or voyage charter at any time to any person without Owner’s consent provided that, as a condition to such sub-chartering, such person undertakes in form and substance
satisfactory to Owner that (i) such person’s rights as sub-charterer are subject and subordinate to Owners’ rights under this Charter, (ii) any sub-charter will include wording consistent with Article 1.6 of the
Consent & Agreement set forth at Schedule VII, and (iii) such person shall not assert any claim against Owner or Owners’ financiers for wrongful interference with its rights (or any similar or equivalent claim) in respect of any
actions taken by Owner or Owner’s financiers in compliance with this Charter and/or the Consent & Agreement (as the case may be). Charterer shall always remain responsible for due fulfillment of this Charter notwithstanding any
sub-chartering. Any other sub-chartering shall require Owner’s prior written consent. 


  

					
	Execution version – Hull No. 1688	 	39	 	










	 	(ii)	Charterer may assign its rights (but not transfer its obligations) to an Affiliated Company provided that Charterer shall always remain responsible for due fulfillment of this Charter notwithstanding such assignment.


  

	 	(iii)	Charterer may transfer or novate its rights and obligations under this Charter to an Affiliated Company (a “Charterer Affiliated Transferee”) subject to the following conditions: 


 

	 	(1)	Owner is satisfied, acting reasonably, that the transfer or novation to the Charterer Affiliated Transferee would not result in any increased liability to Owner or reduced benefits to Owner under this Charter; and


  

	 	(2)	The Consent and Agreement and any other documents ancillary to this Charter are also transferred or novated; and 

  

	 	(3)	Owner receives evidence satisfactory to it of the due authorisation and execution by the Charterer Affiliated Transferee of the documents necessary to implement the foregoing provisions of this sub-clause (a)(iii)


  

	 	(iv)	Any other assignment, transfer or novation of Charterer’s rights and/or obligations under this Charter shall require Owners’ prior written consent, such consent not to be unreasonably withheld, conditioned or
delayed. It shall be reasonable for the Owner to withhold or to condition its consent to a proposed transfer or novation to a proposed transferee pursuant to this sub-clause (a)(iv) (a “Third Party Transferee”) if: 


 

	 	(1)	The creditworthiness of either the Third Party Transferee or, if the Third Party Transferee will provide a guarantee, the creditworthiness of any guarantor of the obligations of the Third Party Transferee is not
reasonably satisfactory to Owner or Owner’s financiers holding Permitted Encumbrances; 

  

	 	(2)	the Third Party Transferee or any Affiliated Company of the Third Party Transferee is involved in an actual or threatened legal dispute or arbitration with Owner or any Affiliated Company of Owner. For purposes of this
paragraph (2) “threatened legal dispute or arbitration” means any dispute in respect of which either the Third Party Transferee or any Affiliated Company of the Third Party Transferee has indicated in writing that it intends to issue
or commence legal or arbitration proceedings against Owner or any Affiliated Company of Owner; 

  

	 	(3)	it would be unlawful or contrary to applicable sanctions affecting Owner or any Affiliated Company of Owner for Owner to charter to the Third Party Transferee; or 


 

	 	(4)	the Third Party Transferee is not able to demonstrate to Owner’s reasonable satisfaction that it has the experience required to fulfil the obligations of Charterer hereunder. 


  

					
	Execution version – Hull No. 1688	 	40	 	










	(b)	By Owner 

  

	 	(i)	Owner may assign (by way of security) and/or grant a security interest in the Vessel to its lenders without Charterer’s consent, provided any encumbrances resulting from such assignment and/or grant of a security
interest shall qualify as Permitted Encumbrances. 

  

	 	(ii)	Owner may novate or transfer its rights and obligations under this Charter and sell the Vessel to any Affiliated Company of Höegh LNG Ltd (“Höegh”) or Mitsui O.S.K. Lines, Ltd. (“MOL”) (an
“Owner Affiliated Transferee”) subject to the following conditions: 

  

	 	(1)	Owner’s Guarantee is confirmed to apply to the obligations of the Owner Affiliated Transferee or is replaced by a new guarantee from either Höegh or MOL (as applicable) of the obligations of the Owner
Affiliated Transferee but otherwise in substantially identical terms to the Owner’s Guarantee except as to several and proportionate liability; 

  

	 	(2)	Charterer is satisfied, acting reasonably, that the Owner Affiliated Transferee has sufficient financial resources and has, or has access to, sufficient management and operational resources to perform its obligations
under this Charter; 

  

	 	(3)	Charterer is satisfied, acting reasonably, that the transfer or novation to the Owner Affiliated Transferee would not result in any increased liability to Charterer or reduced benefit to Charterer; 


 

	 	(4)	The Consent and Agreement and any other documents ancillary to this Charter are also transferred or novated; and 

  

	 	(5)	Charterer receives evidence satisfactory to it of the due authorisation and execution by the Owner Affiliated Transferee and the applicable Owner’s Guarantor(s) of the documents necessary to implement the foregoing
provisions of this sub-clause (b)(ii). 

  

	 	(iii)	Owner may enter into a tax lease financing for the Vessel and may, for purposes of putting into place a tax lease structure, make such changes (subject to Charterer’s approval) to the ownership and quiet enjoyment
arrangement relating to the Vessel as are required under the tax lease structure, provided that Owner and Charterer shall agree in advance such arrangements for putting a tax lease structure into place, including the arrangements for sharing of any
benefits derived by Owner from such tax lease financing as mutually agreed by the Parties, and provided that any encumbrances resulting therefrom shall qualify as Permitted Encumbrances. 


 

	 	(iv)	Any other assignment, transfer or novation of Owner’s rights and/or obligations under this Charter shall require Charterer’s prior written consent. 


  

					
	Execution version – Hull No. 1688	 	41	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	22.	Final Voyage 

  

	(a)	If, when a payment of hire is due hereunder, Charterer reasonably expects to redeliver the Vessel before the next payment of hire would fall due, the hire to be paid shall be assessed on Charterer’s reasonable
estimate of the time necessary to complete Charterer’s program up to Redelivery, and from which estimate Charterer may deduct amounts due or reasonably expected to become due for: 


 

	 	(i)	disbursements on Owner’s behalf or charges for Owner’s account pursuant to any provision hereof; and 

  

	 	(ii)	bunkers, LNG, and marine gas oil on board at Redelivery pursuant to Clause 18. 

 Within *****
days after Redelivery any overpayment shall be refunded by Owner or any underpayment made good by Charterer. 
  

	(b)	If, at the time this Charter would otherwise expire or terminate in accordance with Clauses 5 and 6, the Vessel is on a ballast voyage to a port of redelivery or is upon a laden voyage, Charterer shall continue to have
the use of the Vessel at the same rate and conditions as then in effect herein for as long as necessary to complete such ballast voyage, or to complete such laden voyage and return to a port of redelivery as provided by this Charter, as the case may
be. 

  

	23.	Loss of Vessel 

 Should the Vessel be lost, this Charter shall terminate and hire shall cease at noon GMT
on the day of her loss; should the Vessel be a constructive or compromised total loss, this Charter shall terminate and hire shall cease at noon GMT on the day on which the Vessel’s underwriters agree that the Vessel is a constructive or
compromised total loss; should the Vessel be missing, this Charter shall terminate and hire shall cease at noon GMT on the day on which she was last heard of. Any hire paid in advance and not earned shall be returned to Charterer and Owner shall
reimburse Charterer for the value of the estimated quantity of bunkers and marine gas oil on board at the time of termination, at the price paid by Charterer (or by Owner for Charterer’s account) at the last place of supply. 

 

	24.	Off-hire 

  

	(a)	On each and every occasion that there is loss of time (whether by way of interruption in the Vessel’s service or from reduction in the Vessel’s performance, or in any other manner): 


 

	 	(i)	 due to deficiency of personnel or stores, repairs, gas freeing for repairs, time in and awaiting to enter dry-dock for repairs; breakdown (whether
partial or total) of machinery, boilers or other parts of the Vessel or her equipment (including without limitation ballast tank coatings); but excluding always a failure or 



  

					
	Execution version – Hull No. 1688	 	42	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
breakdown of the Regasification Components (in respect of which the provisions of Clause 27(g) shall apply); collision, stranding, accident or damage to the Vessel or any other similar cause
preventing the efficient working of the Vessel, and such loss continues for more than ***** consecutive hours (if resulting from interruption in the Vessel’s service) or cumulates to more than ***** hours (if resulting from partial loss of
service); or 

  

	 	(ii)	due to industrial action, refusal to sail, breach of orders or neglect of duty on the part of the master, officers or crew; or 

  

	 	(iii)	for the purpose of obtaining medical advice or treatment for or landing any sick or injured person (other than Charterer’s representatives carried under Clause 20) or for the purpose of landing the body of any
person (other than Charterer’s representatives carried under Clause 20) and such loss continues for more than ***** consecutive hours, but no loss of time shall be counted for obtaining medical advice or treatment for the master, officers or
crew as a result of their having had communication with the shore at any infected area subject to quarantine when such communication was with the written consent or instructions of Charterer or its agent; or 


 

	 	(iv)	due to any delay in quarantine arising from the master, officers or crew having had communication with the shore at any infected area without the written consent or instructions of Charterer or its agents, or to any
detention by customs or other authorities caused by smuggling or other infraction of local law on the part of the master, officers or crew; or 

  

	 	(v)	due to detention (including denial of night transiting normally allowed LNG tankers at the port of destination of the Vessel) of the Vessel by authorities at home or abroad, offshore or in port, attributable to legal
action against, or breach of regulations by, or inspections required of, the Vessel or Owner (unless brought about by the act or neglect of Charterer); or 

  

	 	(vi)	except as provided in Clause 25(g), proceeding to or from and while at any port or anchorage other than that to which the Vessel is bound under the instructions of Charterer for any reason other than stress of weather;
or 

  

	 	(vii)	except as provided in Clause 25(g), due to any repairing and unscheduled dry-docking, including time spent for pre-dry docking/repair procedure, including inserting, purging and gas freeing, post-dry-docking/repair
procedure, including inserting, purging and cooling in excess of that undertaken at normal loading, and waiting for any of the aforesaid purposes; 

  

	 	(viii)	due to requisition as specified in Clause 35; 

  

	 	(ix)	due to any other circumstances where the Vessel is off-hire under this Charter; or 

  

	 	(x)	due to the circumstances under which the Vessel is off-hire as provided for in Clauses 7(e), 7(h), 7(k) and 7(o), 


  

					
	Execution version – Hull No. 1688	 	43	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 then without prejudice to Charterer’s rights under Clause 4 or otherwise, the Vessel
shall be off-hire from the commencement of such loss of time until she is again ready and in an efficient state to resume her service from a position not less favorable to Charterer than that at which such loss of time commenced; provided, however,
that any service given or distance made good by the Vessel while off-hire (and the cost of bunkers, diesel oil, marine gas oil and boil-off which would have been used or lost to give such service or make good such distance while off-hire) shall be
taken into account in assessing the amount to be deducted from hire, and provided further that all reasonable costs and expenses incurred in respect of any general maintenance works unrelated to any cause or event contemplated in this Clause 24(a)
and conducted while the Vessel is off-hire shall, to the extent such costs and expenses are contemplated in Schedule III, constitute operating expenses forming part of the Variable Element of hire and shall be paid for in accordance with the
provisions of Schedule III. 
  

	(b)	Further and without prejudice to the foregoing, in the event of the Vessel deviating (which expression includes without limitation putting back, or putting into any port other than that to which she is bound under the
instructions of Charterer) for any cause or purpose mentioned in Clause 24(a), the Vessel shall be off-hire from the commencement of such deviation until the time when she is again ready and in an efficient state to resume her service from a
position not less favorable to Clatterer than that at which the deviation commenced; provided; however, that any service given or distance made good by the Vessel while so off-hire shall be taken into account in assessing the amount to be deducted
from hire. If the Vessel, for any cause or purpose mentioned in Clause 24(a), puts into any port other than the port to which she is bound on the instructions of Charterer, the port charges, pilotage and other expenses at such port shall be borne by
Owner. Should the Vessel be driven into any port or anchorage by stress of weather, hire shall continue to be due and payable during any time lost thereby. 

  

	(c)	If the Vessel’s Flag State becomes engaged in hostilities, Owner shall, at the request of Charterer, change the Vessel’s flag to a flag of a state free of hostilities if it is reasonably practicable to do so.
The costs of such change of flag shall be borne by Charterer. If Owner is unable to change the Vessel’s flag as aforesaid and Charterer, in consequence of such hostilities, finds it commercially impracticable to employ the Vessel, and has given
Owner written notice thereof, then from the date of receipt by Owner of such notice until the termination of such commercial impracticability, the Vessel shall be off-hire and Owner shall have the right to employ the Vessel on its own account.


  

	(d)	Time during which the Vessel is off-hire under this Charter shall count as part of the Initial Charter Period or any extension period, as applicable. 


 

	(e)	If as a consequence of any cause or purpose mentioned in this Clause 24 or in Clause 47(b), the Vessel presents for loading with tank temperatures other than that which would otherwise allow bulk loading to commence
within ***** minutes after cooling of the loading arms, any time lost as a consequence thereof, including, without limitation, any time lost in additional cooling of tanks prior to loading, shall count as off-hire and the cost of any LNG supplied
for such additional cooling shall be paid for by Owner at the LNG price paid by Charterer at the place of current loading. 


  

					
	Execution version – Hull No. 1688	 	44	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(f)	

  

	 	(i)	In the event that the Vessel is off-hire by reason of any damage to the Vessel’s cargo containment system as a result of Owner’s failure to comply with the provisions of Clause 45(a) for any period exceeding
***** months in any period of ***** years, Charterer shall have the option to terminate this Charter. 

  

	 	(ii)	In the event that the Vessel is off-hire for any reason other than (i) in connection with periodic dry-docking pursuant to Clause 25(a) or (ii) any damage to Vessel’s cargo containment system for any
reason other than Owner’s failure to comply with the provisions of Clause 45(a) for any period exceeding ***** months in any period of ***** years, Charterer shall have the option to terminate this Charter. 


 

	 	(iii)	Charterer may exercise its option to terminate in accordance with (i) or (ii) above by giving notice in writing, such notice to be served not later than ***** days after the date on which the Charterer’s
option to terminate arises in accordance with (i) or (ii) above with the termination to take effect on the date stated in such notice, provided that the Vessel is free of cargo (other than LNG heel) at the date of termination; provided
further that Owner shall have the right to provide a substitute vessel having a technical specification, performance capability and condition substantially equivalent to the Vessel to replace the Vessel during such extended period of off-hire as
soon as possible but in any event not later than ***** days after the day on which the Charterer’s option to terminate arises in accordance with (i) or (ii) above (but in any event not later than the expiry of the ***** year period in
(i) above or the ***** year period in (ii) above, as applicable), in which case Charterer shall not be entitled to terminate the Charter under this Clause 24(f). In the event Owner does not have access to such substantially equivalent
vessel, Owner may nonetheless offer to Charterer its available vessel(s) and Charterer may accept such vessel(s). In any such case the parties shall agree upon such adjustments to the hire rate and/or such amendments to the performance warranties as
stipulated in this Charter as are, when compared with the performance capabilities of the Vessel, commensurate with any excesses or deficiencies, as the case may be, in the performance capabilities of the substitute vessel. This Clause 24(f) is
without prejudice to any other rights or obligations of Owner or Charterer under this Charter. For the purposes of this Clause 24(f), in the event of partial loss of service, the period of off-hire shall be the total period during which the Vessel
is not fully efficient rather than the resulting loss of time. 

  

	(g)	Subject to Clause 47 and the proviso in Clause 24(a), all costs including but not limited to bunkers, diesel oil, marine gas oil, port charges and the costs of cool down and boil-off incurred during periods of off-hire
shall be for Owner’s account During periods of off-hire the actual boil-off shall be calculated for the entire period of off-hire. In the event that the actual boil-off cannot be, or has not been, determined for such period or a portion
thereof, the boil-off rate per day shall be deemed to be equivalent to the maximum average daily boil-off provided for in Clause 27(a)(iii) for that portion of the period for which the actual boil-off cannot be, or has not been, determined.



  

					
	Execution version – Hull No. 1688	 	45	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(h)	Owner shall be entitled to an allowance (“Off-hire Allowance”) of ***** days per year counted from the Delivery Date until the ***** anniversary thereof and thereafter for each *****-month period beginning on
each anniversary of the Delivery Date. The off-hire Allowance shall be applied in each such *****-month period against the first ***** days when the Vessel is off-hire under this Clause 24. Notwithstanding the foregoing, the Off-hire Allowance may
not be cumulated from year to year and may only be used in the *****-month period in which it accrues. Owner shall promptly notify Charterer of any Off-hire Allowance taken and the reason therefor. During the Off-hire Allowance period, Charterer
shall continue to pay hire, but such payment shall be the only obligation of Charterer, and specifically excluding payment of any bunkers, boil-off or any other costs and liabilities accruing from such period. 


 

	25.	Dry-docking; Time for Scheduled Maintenance 

  

	(a)	Owner shall dry-dock, clean and paint the Vessel’s bottom and effect scheduled maintenance at no less than *****-month intervals and no more than *****-month intervals (or at such other intervals as Owner and
Charterer may mutually agree which best conform to Charterer’s requirement and to requirements for safety of the Vessel, its cargo, officers and crew and of any relevant government authorities and the Classification Society), so that the Vessel
is fitted in every way for service under this Charter and for which purpose Charterer shall allow the Vessel to proceed to an appropriate port. The first such dry-docking shall be within the period necessary for the Vessel to remain qualified for
all warranties and guarantees of Builder under the Building Contract. Owner shall be solely responsible for implementing any dry-docking and also for gas freeing the Vessel. Upon the occasion of each such dry-docking, Owner shall notify Charterer in
writing at least ***** months in advance for the guarantee repairs and ***** months otherwise. Furthermore, Owner will make reasonable efforts to provide Charterer ***** mouths’ written notice of each dry-docking other than guaranteed repairs.


  

	(b)	Owner’s selection of a yard for a scheduled dry-docking and any other scheduled maintenance and repairing pursuant to Clause 25(a) shall be subject to approval by Charterer. The selection of the yard shall take
into account the quality of the yard and the trade in which Vessel is then engaged. 

  

	(c)	Owner shall inform Charter in writing of the proposed specification for each scheduled dry-docking to be carried out pursuant to Clause 25(a) (which shall include, without limitation, the estimated costs of the
scheduled drydocking work and any anticipated time out of service) and give written notice thereof to Charterer at least ***** days prior to the proposed commencement of the dry-docking (or at such other time as the parties may agree); provided,
however, that in the case of any unscheduled dry-docking, Owner shall consult with Charterer and submit a budget estimate (with any drydocking/maintenance/repair quotation from the agreed drydocking yard) which the parties shall consider with a view
to agreeing on such estimate, as far in advance thereof as possible and obtain Charterer’s written consent thereto. Charterer shall not unreasonably withhold or delay its consent to any such proposed dry-docking. 


  

					
	Execution version – Hull No. 1688	 	46	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(d)	Owner may, with Charterer’s prior written consent (such consent not to be unreasonably withheld or delayed), carry out unscheduled maintenance, including the inspection and maintenance of the Vessel’s boilers
and cargo and spray pumps, bottom cleaning and hull inspection while the Vessel is afloat, and take the Vessel out of service, if so required by such unscheduled maintenance or repairs (“Unscheduled Maintenance”). In addition to the
Drydocking Allowances provided for under Clause 25(g) and without prejudice to the provisions of Clause 27(i), Owner shall be entitled to the following allowances (the “Unscheduled Maintenance Allowances”) of: 


*****and thereafter such Unscheduled Maintenance Allowances shall apply for every ***** ***** period (the “Allowance Period”)
commencing from the first day of the ***** and thereafter from the first day of the first year of each subsequent Allowance Period. Owner shall notify Charterer of any Unscheduled Maintenance Allowance to be taken and shall consult with Charterer as
far in advance as possible as regards the timing of any such Unscheduled Maintenance. The Unscheduled Maintenance Allowance may not be accumulated from year to year in any Allowance Period, and shall be subject to reduction, if any, in accordance
with the provisions of Clause 27(i)(ii). 
  

	(e)	Owner shall use all reasonable efforts to arrange scheduled maintenance on the Vessel during periods acceptable to Charterer, and to minimize the amount of time utilized for such maintenance. Owner shall not, without
the consent of Charterer, arrange scheduled maintenance during the period 1 September to 31 March. 

  

	(f)	Owner shall ensure that all maintenance and repair of the Vessel from the date of this Charter until the end of the Term conforms to the Master Maintenance and Repair Plan, as supplemented by classification society
rules and prudent operating practices as adopted on first-class LNG-carrying and SRV vessels. The Master Maintenance and Repair Plan shall specifically address the maintenance and repair of the Regasification Components of the Vessel. Owner shall
propose a Master Maintenance and Repair Plan for Charterer’s approval (such approval not to be unreasonably withheld, conditioned or delayed) no later than ***** months prior to the Anticipated Delivery Date, such initial plan to be updated
annually by agreement no later than October 30th of each year during the Term. Should there be a significant interruption or frequent interruptions in the availability of the Vessel or other under-performance, Owner shall, in consultation with
Charterer, modify the Master Maintenance and Repair Plan and/or take any other action that may be necessary to ensure the satisfaction of Charterer that such interruption or under-performance does not recur. 


 

	(g)	The Vessel will remain on hire for the following periods (“Drydocking Allowances”) in respect of each scheduled drydocking: 


 

	 	(i)	a period up to ***** days to carry out pre-docking and repair procedures, such as warming, inerting, gas freeing (including the ballast voyage time between the immediately prior discharge port and the drydocking
shipyard); plus 

  

	 	(ii)	 a period not exceeding ***** days during the first ***** dry-dockings, (subject, in respect of the first dry-docking, to such ***** day period being
sufficient to 



  

					
	Execution version – Hull No. 1688	 	47	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
complete a check of the Vessel’s cargo containment system in accordance with the Builder’s guarantee under the Building Contract) and twenty (20) days for each dry-docking
thereafter, in each case commencing from six hours after arrival at the pilot station off the drydocking port to dropping outward pilot off the drydocking port; plus 


 

	 	(iii)	a period not to exceed ***** days, for post docking and repair procedures and any purging, gassing up or cooling in excess of that taken for normal loading; 


 

	 	(iv)	any deviation proceeding to and from the drydocking port provided the Vessel proceeds at normal speeds on such voyage. 


To the extent that the pre-docking and repair procedures or, as the case may be, the post-docking and repair procedures, can be carried out
while the Vessel is proceeding on a ballast voyage from the last discharge port to the approved selected drydocking port (for pre-docking and repair procedures) or from the approved selected drydocking port to the first loading port (for
post-docking and repair procedures) the allowance times above will be reduced taking into account the time saved in carrying out such procedures during such normal ballast voyage. Owner will use all reasonable endeavours to minimize the time that
the Vessel is out of service for drydocking (including, for avoidance of doubt, time to carry out, to the extent practicable, pre- and post-drydocking procedures during ballast voyages to and from the last approved dry-docking port), annual class
survey and maintenance and so far as is reasonably practicable shall ensure that any annual class survey in the drydocking year shall be carried out in conjunction with any scheduled drydocking. 

To the extent that the number of days used in scheduled drydocking exceeds the Drydocking Allowances, the Vessel shall be off-hire and the
provisions of Clause 24 shall apply; provided however that if Charterer required additional work to be completed during any scheduled dry-docking which cannot be completed during the period of relevant Dry-Docking Allowances, then the Vessel shall
not be off-hire to the extent that the relevant Dry-Docking Allowance is exceeded to complete such works. 
  

	(h)	Owner may at any time, with Charterer’s prior approval (not to be unreasonably withheld or delayed), order the Vessel into a dry-dock or a shipyard to correct a defect in the Regasification Components. Owner shall
cooperate with Charterer in scheduling any such dry docking or other repair so as to minimize the impact on Charterer’s operations of the Vessel’s temporary withdrawal from service. During any such period of dry-dock or other repair, the
Vessel shall be off-hire and all costs incurred in respect of the repair or correction of such defect in the Regasification Components or as a result of the Vessel entering, remaining in, breaking or leaving dry-dock or the shipyard shall be
operating costs forming part of the Variable Element under Schedule III (provided however that all costs saved or avoided due to warranties under the Building Contract shall not be paid by Charterer). 


 

	(i)	 No later than ***** months prior to the Anticipated Delivery Date Owner shall provide to Charterer a draft SRV Operating Manual for Charterer’s
approval (such approval not 



  

					
	Execution version – Hull No. 1688	 	48	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
to be unreasonably withheld, conditioned or delayed). The SRV Operating Manual shall be updated prior to delivery of the Vessel and thereafter annually by agreement no later than
October 30th of each year during the Term. The SRV Operating Manual shall include, among other things, a description of the activities and operation of the crew, the Regasification Components, the Buoy System and the requirements applicable to
cargo management and filling level restrictions when the Vessel is connected to the Buoy System and/or discharging regasified LNG; provided, however that the SRV Operating Manual shall not restrict the master’s rights to order the Vessel or its
crew to take any action the master determines to be necessary to preserve life and property at sea. 

  

	26.	Ship Inspection 

 Charterer shall have the right at any reasonable time after Delivery of the Vessel and
during the Term of this Charter (including during any dry-docking) to make such inspection of the Vessel as it may consider necessary. This right may be exercised as often and at such intervals as Charterer in its absolute discretion may determine
and whether the Vessel is in port or on passage. Owner shall afford all necessary cooperation and accommodation on board; provided, however, that (i) such inspections shall not interfere with or cause any delay in the operation of the Vessel,
(ii) all costs and expenses of such inspections shall be for account of Charterer, and (iii) neither the exercise nor the non-exercise, nor anything done or not done in the exercise or non-exercise, by Charterer of such right shall in any
way reduce the master’s or Owner’s authority over, or responsibility to Charterer or third parties for, the Vessel and every aspect of her operation, nor increase Charterer’s responsibilities to Owner or third parties for the same.
If, following any such inspection or at any other time, the Vessel does not comply with the requirements set forth for the Vessel in this Charter, then at the request of Charterer, Owner shall submit to Charterer in writing a plan to remedy the
defect(s) as soon as reasonably possible and in any event not later than ***** days after Charterer’s request (unless extended by Charterer). 
  

	27.	Performance 

  

	(a)	Owner undertakes and guarantees that at all times during the currency of this Charter, the Vessel shall be capable of maintaining: 

  

	 	(i)	an average speed per round trip voyage of no less than 19.5 knots, in moderate weather conditions up to and including Force 5 on the Beaufort Scale. At Charterer’s request, and provided that it is consistent with
the safety of the Vessel, Owner shall use best efforts to steam at a speed faster than 19.5 knots; provided that the fuel consumed during such periods of fast steaming shall be excluded from the calculation of fuel consumption for the purpose of
Clause 27(a)(ii); 

  

	 	(ii)	 a consumption of no more than about ***** metric tons of marine diesel oil per day or ***** tons of heavy fuel oil per day for purposes of propulsion
only when boil-off gas is not available. When boil-off is available, such guaranteed fuel oil consumption shall be reduced by the amount of such boil-off, measured in terms of its equivalency to fuel oil. Initially, one cubic meter (1m3) of boil-off gas shall be deemed equivalent to 0.55 metric tons of fuel oil (“BOE”), based on the equivalency of the fuel oil used on the Vessel’s first laden voyage under this




  

					
	Execution version – Hull No. 1688	 	49	 	










	 	
Charter and the composition of the LNG transported on said voyage. Subsequently, the BOE shall be reviewed and revised by mutual agreement between Owner and Charterer from time to time to reflect
changes in the composition of the LNG loaded; 

  

	 	(iii)	a maximum average daily boil-off of no more than 0.15% of the Vessel’s total cargo capacity measured on a laden voyage basis and no more than 0.10% of the Vessel’s total cargo capacity measured on a ballast
voyage basis; and 

  

	 	(iv)	the ability to discharge cargo in conformance with the specifications of Schedule I. 

  

	(b)	

  

	 	(i)	The average speed and fuel consumption rates specified above shall be calculated by reference to the observed distance from FAOP (full away on sea passage) to EOP (end of sea passage) per round trip voyage during each
period stipulated in Clause 27(d), but excluding any time when the Vessel is off-hire pursuant to Clause 24 and also excluding “Adverse Weather Periods”, being (i) any period during which reduction of speed is necessary for safety in
congested waters or in poor visibility and (ii) any days, noon to noon, when winds reach up to and including Force 5 on the Beaufort Scale for more than 6 hours in aggregate. 


 

	 	(ii)	Boil-off calculation 

  

	 	(1)	The boil off excess on any sea passage shall be calculated by comparing the guaranteed boil off for the sea passage (i.e. the daily guaranteed boil off multiplied by the time between gaugings) with the actual boil off.


  

	 	(2)	The actual amount of boil off on a sea passage shall be calculated by subtracting the volume of LNG contained in the Vessel’s tanks at gauging after the sea passage from the volume therein at gauging before the sea
passage, less any LNG used for propulsion purposes resulting from forced vaporization; provided, however, that forced vaporization may only occur at Charterer’s request. 


 

	(c)	If for any round trip voyage during any Performance Period, the Vessel falls below guaranteed in Clause 27(a)(1)-(iv), then (subject to Clause 27(b)(i)), if such under performance results: 


 

	 	(i)	from a reduction in the average speed of the Vessel, compared to the speed specified in Clause 27(a)(i), or any inability of the Vessel to meet the discharge requirements of 27(a)(iv), then an amount equal to the value
at the hire rate of the time so lost shall be deducted from the hire paid; or 

  

	 	(ii)	 from an increase in the total fuel oil (or fuel oil equivalent) consumed, compared to the total fuel oil (or fuel oil equivalent) that would have been
consumed had the Vessel performed as specified in Clause 27(a)(ii) and (a)(iii), then an amount 



  

					
	Execution version – Hull No. 1688	 	50	 	










	 	
equal to the value of the additional fuel oil (or fuel oil equivalent) consumed, based on the price of fuel on board the Vessel at the time of under-performance paid by Charterer and/or any
affiliate of Charterer for fuel oil in such period, shall be deducted from the hire paid. 

 The deduction from hire so
calculated for laden and ballast mileage shall be adjusted to take into account the mileage steamed in each such condition during Adverse Weather Periods, by dividing such deduction by the number of miles over which the performance has been
calculated and multiplying by the same number of miles plus the miles steamed during the Adverse Weather Periods, in order to establish the total deduction from hire to be made for such period. 

Reduction of hire under this Clause 27(c) shall be without prejudice to any other remedy available to Charterer. 

 

	(d)	Calculations under this Clause 27 shall be made for each Performance Period during the Term of this Charter, and any payments due to Charterer shall be credited as against hire payments in accordance with Clause 12 as
promptly as possible. Any necessary adjustment to hire under this Clause 27 after this Charter terminates (whether such termination is in respect of the Initial Charter Period or an extension period), shall be made promptly after such termination by
payment by Owner to Charterer or by Charterer to Owner as the case may require. 

  

	(e)	The following time and any distance traversed during such time shall be excluded from calculations under this Clause 27: 

  

	 	(i)	time lost for stops at sea or any other time at sea which is considered a period of off-hire under this Charter; 

  

	 	(ii)	time lost solely for reasons of safe navigation; 

  

	 	(iii)	time spent steaming at reduced or accelerated speed at the instruction of Charterer (including time spent steaming at Charterer’s instruction with boil-off gas only when insufficient boil-off gas is available to
maintain warranted speed) or during stops at sea as requested by Charterer; 

  

	 	(iv)	time spent for the purpose of saving life or property; 

  

	 	(v)	time spent steaming at reduced speed by mandatory order of regulatory bodies having jurisdiction over the Vessel; 

  

	 	(vi)	time spent steaming at reduced speed as a result of fouling caused by extraordinary delays in port, beyond Owner’s control, or as the result of lay-up at Charterer’s instructions; 


 

	 	(vii)	time lost due to delays resulting from Charterer’s orders or Charterer’s scheduling; 


  

					
	Execution version – Hull No. 1688	 	51	 	










	 	(viii)	time for navigating such restricted areas as Malacca-Singapore Straits, Suez Canal and other areas to be mutually agreed from time to time; 


 

	 	(ix)	time taken for bunkering during a sea passage in accordance with Charterer’s instructions or with Charterer’s consent, such consent not to be unreasonably withheld, conditioned or delayed; and


  

	 	(x)	time taken for scheduled maintenance under Clause 25. 

  

	(f)	When the Vessel is discharging cargo as a conventional LNG carrier, Owner further undertakes that, provided shore installations can receive at the rate specified in paragraph 4 of Appendix I to Schedule I and also
provided that the shore installation supplies a suitable gas return line capable of providing an adequate volume of return vapour to the Vessel to compensate for the displacement of LNG being discharged from the Vessel, the main cargo pumps will,
throughout the Term, discharge the Vessel’s cargo in not more than the number of hours specified in paragraph 4 of Appendix I to Schedule I. Time for stripping, connecting, disconnecting, purging and cooling of shore liquid arms and/or piping
and custody transfer measurement shall not be included in the computation of discharge time. 

  

	(g)	

  

	 	(i)	Owner further undertakes, subject to the provisions of paragraph 10 of Appendix I to Schedule I, that the Regasification Components will, throughout the Term, enable the Vessel’s cargo to be regasified and
discharged at not less than a regasified LNG discharge rate, varying on a monthly basis, at corresponding pressures and temperatures, as specified in paragraph 11 of Appendix I to Schedule I (“Normal Performance”). 


 

	 	(ii)	If, on any day, commencing from 10.00 A.M. (Boston local time) on that day and ending at 09.59 A.M. (Boston local time) on the immediately following day during a Discharge Period (a “Gas Day”), the
Vessel’s actual discharge rate calculated over that Gas Day (the “Actual Discharge Rate”) as measured in accordance with the provisions of paragraphs 9 and 10 of Appendix I to Schedule I is less than the daily nominated discharge rate
requested by Charterer in accordance with the Gas Nomination Procedures for that Gas Day (the “Nominated Discharge Rate”), and such Actual Discharge Rate is lower than Normal Performance (such deficient performance hereinafter being
referred to as “Reduced Performance”), then Charterer shall be entitled to pay hire at a rate equal to the Reduced Rate as calculated in accordance with paragraph 4 of Schedule III. For the avoidance of doubt, any reduction of hire to
which Charterer is entitled under this Clause 27(g) shall be credited as against hire payments in accordance with Clause 12(a) as promptly as possible. In the event of a discharge performed in a location having a gas day other than the Gas Day
defined above, then the definition of Gas Day shall, for particular discharge, be deemed to be the gas day applicable at such alternate location. 


  

					
	Execution version – Hull No. 1688	 	52	 	










	 	(iii)	Subject to the provisions of Clause 27(g)(iv) below, Owner shall use reasonable endeavours to accommodate intra-daily fluctuations of the Nominated Discharge Rate requested by Charterer in accordance with the procedure
for requesting and establishing daily and intra-day nominations as set forth in paragraph 9 of Schedule X (the “Gas Nomination Procedures”). 

  

	 	(iv)	Whenever Charterer requests a Nominated Discharge Rate above Normal Performance, Owner shall use reasonable endeavours to make such higher rate available, subject always to the maximum capacity of the Regasification
Components when all three units of the Regasification Components are operating. Notwithstanding the provisions of Clause 27(g)(ii) above, if the Vessel is incapable of discharging its cargo at such higher rate, such performance shall not be
considered Reduced Performance and Charterer shall not be entitled to pay hire at a rate equal to the Reduced Rate or, claim a reduction in hire. 

  

	 	(v)	If at the beginning of or during a Discharge Period it is evident that the Actual Discharge Rate is below 250 MMScf/day and the Vessel will not be able to rectify the deficiency in the discharge rate by achieving a
higher Actual Discharge Rate within the next forty-eight (48) hours for reasons other than the occurrence of one or more of the events set out in paragraph 10 of Appendix I to Schedule I, then Charterer may instruct the Vessel to proceed to
another Class I Unloading Terminal to discharge its cargo as LNG. In such an event, (1) Charterer shall be entitled to pay hire equal to the relevant Reduced Rate from the beginning of that Discharge Period or from the time that it is evident
that the Actual Discharge Rate is below 250 MMScf/day until the time that the Vessel has discharged its cargo as LNG in full at the selected Class I Unloading Terminal, and (2) thereafter, upon discharge of its cargo as LNG in full, the Vessel
shall be off-hire and shall remain off-hire until Owner has notified Charterer that the Vessel’s capability to discharge regasified LNG at Normal Performance has been reinstated; provided that the Vessel shall not be on hire thereafter until
she is in a geographical position no less favourable to Charterer than the geographical position at which she went off-hire. Notwithstanding the foregoing, any distance made good by the Vessel whilst off-hire under the provisions of this Clause
27(g)(v) (including the cost of bunkers, diesel oil, marine gas oil and boil-off which would have been used or lost to make good such distance while so off-hire) shall be taken into account in assessing the amount to be deducted from hire during any
such Discharge Period. 

  

	 	(vi)	Notwithstanding the provisions of this Clause 27(g), if at any stage the actual discharge rate achieved by the Vessel is less than Nominal Performance due to a defect in the Regasification Components (and such lower
discharge rate has not been requested by Charterer in accordance with the Gas Nomination Procedures), Owner shall be entitled to repair such defect in the Regasification Components and/or the Vessel by the Vessel proceeding to dry-docking in
accordance with the provisions of Clause 25(h). 


  

					
	Execution version – Hull No. 1688	 	53	 	










	(h)	In addition, Owner undertakes that throughout the Term the Vessel will be able to connect to and disconnect from the Buoy System in the manner and in not more than the number of hours specified in paragraph 12 of
Appendix I to Schedule I. 

  

	(i)	

  

	 	(i)	Notwithstanding the provisions of Clause 27(e)(vi), if Owner has good reason to believe the performance of the Vessel or her fuel consumption is affected and the speed and/or fuel warranties as stipulated in this Clause
27 can no longer be met as a result of fouling, then Owner shall so notify Charterer in writing and shall be entitled to carry out an underwater inspection to see if there is fouling of the Vessel’s hull and/or propeller. 


 

	 	(ii)	If the aforesaid underwater inspection shows that there is fouling of the Vessel’s hull and/or propeller, then, if Charterer so requests, Owner shall arrange and carry out cleaning afloat of the Vessel’s
underwater hull and propeller provided that such cleaning afloat: 

  

	 	(1)	can be carried out safely at a place approved by Owner and where the water is sufficiently clear for an underwater survey to be made of the cleanliness of the Vessel’s hull and propeller immediately thereafter; and


  

	 	(2)	will not, in Owner’s reasonably held opinion, damage the Vessel’s underwater hull coatings in any way; and 

  

	 	(3)	is permitted by the relevant port authority. 

 Such cleaning afloat may take place when the
Vessel is connected to the Buoy System, subject always, however, to paragraphs (1) to (3) of the proviso of this paragraph (ii) being satisfied. 

The Vessel shall remain on hire for the duration of such underwater hull and propeller cleaning and any underwater survey; provided that the
Unscheduled Maintenance Allowance under Clause 25(d) shall be reduced by the time taken to complete such underwater hull and propeller cleaning and any underwater survey or inspection, and the cost of such underwater hull and propeller cleaning and
any underwater survey shall be an operating cost forming part of the Variable Element and shall be reimbursed to Owner in accordance with the provisions of Schedule III. 

If the underwater survey following such cleaning afloat shows that the Vessel’s underwater bull and propeller are clean, a successful
cleaning afloat shall be deemed to have occurred. 
  

	 	(iii)	 If any underwater inspection pursuant to Clause 27(i)(i) reveals the presence of fouling of the Vessel’s hull or propeller, then from the time of
Owner’s written notice under Clause 27(i)(i) that the Vessel’s performance is affected by fouling, Owner shall be relieved of all of its obligations under Clauses 27(a) to (c) to the




  

					
	Execution version – Hull No. 1688	 	54	 	










	 	
extent such obligations are affected by fouling and shall be deemed to have complied with the speed and fuel warranties stipulated under this Clause 27, to the extent such obligations are
affected by fouling until the earlier of (1) the completion of the next scheduled drydocking and (2) the successful cleaning afloat. 

  

	28.	Salvage 

 Subject to the provisions of Clause 24, all loss of time and all expenses (excluding any damage
to or loss of the Vessel or tortious liabilities to third parties) incurred in saving or attempting to save life or in successful or unsuccessful attempts at salvage, shall be borne equally by Owner and Charterer; provided, however, that Charterer
shall not be liable to contribute towards any salvage payable by Owner arising in any way out of services rendered under this Clause 28. 
 All salvage and
all proceeds from derelicts shall be divided equally between Owner and Charterer after deducting the master’s, officers’ and crew’s share. 
  

	29.	Lien and Quiet Enjoyment 

  

	(a)	Owner shall not, other than Permitted Encumbrances, have and shall not allow others (claiming through Owner), to have a lien upon any cargoes, fuel, freights, sub-freights and/or sub-hires and demurrage except to the
extent that any such lien arises by operation of law. 

  

	(b)	Charterer shall not have and shall not allow others (in their dealings with Charterer) to the extent they lawfully may, to have a lien on the Vessel except to the extent that any such lien arises by operation of law.


  

	(c)	In the event that any lien shall attach by operation of law or in violation of this Clause 29, Owner or Charterer, as the case may be, shall take such steps as are reasonably necessary to ensure that the lien does
not interfere with the Vessel’s operations and to effect prompt release of such lien prior to the enforcement thereof. 

  

	30.	Exceptions 

  

	(a)	The Vessel, her master and Owner shall not, unless otherwise in this Charter expressly provided, be liable for any loss or damage or delay or failure arising or resulting from any act, neglect or default of the master,
pilots, mariners or other servants of Owner in the navigation or management of the Vessel; fire, unless caused by the actual fault or privity of Owner; collision or stranding; dangers and accidents of the sea; explosion, bursting of boilers,
breakage of shafts or any latent defect in hull, equipment or machinery; provided, however, that Clauses 2, 3, 4 and 27 hereof shall be unaffected by the foregoing. Further, neither the Vessel, her master or Owner nor Charterer shall, unless
otherwise in this Charter expressly provided, be liable for any loss or damage or delay or failure in performance hereunder arising or resulting from act of God, act of war, seizure under legal process, quarantine restrictions, strikes, lock-outs,
riots, restraints of labor, civil commotions or arrest (in each case unless caused by the failure of the party seeking the benefit of the exception to exercise due diligence), or restraint of princes, rulers or people. 


  

					
	Execution version – Hull No. 1688	 	55	 	










	(b)	The Vessel shall have liberty to sail with or without pilots, to tow or go to the assistance of vessels in distress and to deviate for the purpose of saving life or property. 


 

	(c)	Clause 30(a) shall not apply to or affect any liability of Owner or the Vessel or any other relevant person in respect of: 

  

	 	(i)	loss or damage caused to any berth, jetty, dock, dolphin, buoy, mooring line, pipe or crane or other works or equipment whatsoever at or near any place to which the Vessel may proceed under this Charter, whether or not
such works or equipment belong to Charterer; or 

  

	 	(ii)	any claim (whether brought by Charterer or any other person) arising out of any loss of or damage to cargo, or in connection therewith. All such claims shall be subject to the Hague-Visby Rules or the Hague Rules or the
Hamburg Rules as the case may be, which pursuant to Clause 41 shall be incorporated in the relevant bill of lading (whether or not such Rules were so incorporated), or, if no such bill of lading is issued, to the Hague-Visby Rules unless the Hamburg
Rules compulsorily apply, in which case to the Hamburg Rules. 

  

	(d)	No provision for the payment or cessation of hire, including provisions relating to off-hire and reduction in hire contained in this Charter, shall be affected by the provisions of this Clause 30. 


 

	(e)	Notwithstanding any other provision of this Charter, any liability of Owner or Charterer for loss of or damage to any property and death of or injury to any person arising out of or relating to the use by the Vessel of
any port designated by Charterer shall be subject to such port or terminal regulations or conditions of use and such other terms relating to the use of such port as may from time to time be required by the responsible port or terminal operator,
provided that such port or terminal regulations or conditions of use are reasonably acceptable to reputable insurers and the Approved Club. 

  

	31.	Injurious Cargoes 

 No acids, explosives or cargoes injurious to the Vessel shall be shipped and without
prejudice to the foregoing any damage to the Vessel caused by the shipment of any such cargo, and the time taken to repair such damage, shall be for Charterer’s account. No voyage shall be undertaken, nor any goods or cargoes loaded, that would
expose the Vessel to capture or seizure by rulers or governments. 
  

	32.	Grade of Bunkers 

 Charterer shall supply bunker fuel oil for main propulsion and marine gas oil for the
auxiliaries meeting the specifications set out in Schedule I. 

  

					
	Execution version – Hull No. 1688	 	56	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	33.	Disbursements 

 In exceptional circumstances only, should the master require advances for ordinary
disbursements at any port, Charterer or its agents may, in its sole discretion, make such advances to him, in which case all such advances shall be deducted from hire. 
  

	34.	Laying-Up 

 Charterer shall have the right, after consultation with Owner, to require Owner to lay-up the
Vessel at a safe place mutually agreed in which case the hire provided for under this Charter shall be adjusted to reflect any net increases in expenditure reasonably incurred or any net saving which should reasonably be made by Owner as a result of
such lay-up. Charterer may exercise such right any number of times during the currency of this Charter. During any period of lay-up under this Clause 34, Owner’s duty of maintenance under Clause 4 shall be reduced to the standard ordinarily
applied by prudent owners to vessels of the same type in lay-up and Clauses 24 and 27 shall not apply. Until such time as it is practicable for Owner to complete all work required with respect to fouling (as determined by Owner’s surveyor)
to restore the Vessel to a condition it would have been in if it had not been laid up, any reduction in the Vessel’s performance due to fouling during a lay-up requested by Charterer under this Clause 34 shall not give rise to a performance
claim against Owner. Bottom cleaning, propeller polishing or dry-docking required as a result of lay-up under this Clause 34 shall be for the account of Charterer. 
  

	35.	Requisition 

 Should the Vessel be requisitioned by any government, de facto or de jure, during the
period of this Charter, the Vessel shall be off-hire during the period of such requisition, and any hire paid by such government in respect of such requisition period shall be for Owner’s account. Any such requisition period shall count as part
of the Initial Charter Period or the applicable extension period, if any, as the case may be. 
  

	36.	Outbreak of War 

 If war is declared in any location that materially interrupts the performance of this
Charter, or actually precludes Charterer’s ability to employ the Vessel, Owner and Charterer (as appropriate based on which entity is affected) shall each have the right to terminate this Charter without penalty; provided, however, that the
party seeking to rely upon this Clause 36 has consulted with the other party in good faith and, for a minimum of ***** days after any such outbreak has commenced, each party shall take such steps as may reasonably be available to it (including
without limitation a change in the Vessel’s country of registration) with a view to avoiding or mitigating the effects of such war or hostilities, failing which either party may terminate this Charter forthwith. 

 

	37.	Additional War Expenses 

 The Vessel shall not be ordered to trade in areas where, in Owner’s
reasonable opinion, there is war (de facto or de jure) or threat of war, without Owner’s consent. If the Vessel is so ordered and Owner does consent, Charterer shall reimburse Owner for any additional insurance premiums, crew
bonuses and other expenses which are reasonably incurred by Owner as a 

  

					
	Execution version – Hull No. 1688	 	57	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 
consequence of such orders; provided, however, that Charterer is given written notice of such expenses as soon as practicable and, when possible, before such expenses are incurred and provided
further that Owner obtains from its insurers a waiver of any subrogated rights against Charterer in respect of any claims by Owner under its war risk insurance arising out of compliance with such orders. Any payments by Charterer under this Clause
37 will only be made against substantiating documentation. However, if Owner is not able to maintain from its insurers such a waiver of any subrogated rights against Charterer, Owner shall be entitled to withhold its consent under this Clause 37
unless Charterer undertakes to reimburse Owner for any additional, reasonably incurred and appropriately documented expenses notwithstanding that Owner shall not have been able to obtain such waivers of subrogation. 

 

	38.	War Risks 

  

	(a)	The master shall not be required or bound to sign bills of lading for any place which in his or Owner’s reasonable opinion is dangerous or impossible for the Vessel to enter or reach owing to any blockade, war,
hostilities, warlike operations, civil war, civil commotions or revolutions. 

  

	(b)	If in the reasonable opinion of the master or Owner it becomes, for any of the reasons set out in Clause 38(a) or by the operation of international law, dangerous, impossible or prohibited for the Vessel to reach or
enter, or to load or discharge cargo at, any place to which the Vessel has been ordered pursuant to this Charter (a “place of peril”), then Charterer or its agents shall be immediately notified by telex or radio messages, and Charterer
shall thereupon have the right to order the cargo, or such part of it as may be affected, to be loaded or discharged, as the case may be, at any other place within the trading limits of this Charter (provided such other place is not itself a place
of peril). If any place of discharge is or becomes a place of peril, and no orders have been received from Charterer or its agents within ***** hours after dispatch of such messages, then Owner shall be at liberty to discharge the cargo or such part
of it as may be affected at any place which Owner or the master may in its or his discretion select within the trading limits of this Charter and such discharge shall be deemed to be due fulfillment of Owner’s obligations under this Charter so
far as the cargo so discharged is concerned. 

  

	(c)	The Vessel shall have liberty to comply with any directions or recommendations as to departure, arrival, routes, ports of call, stoppages, destinations, zones, waters, delivery or in any other wise whatsoever given by
the government of the Flag State or any other government or local authority or by any person or body acting or purporting to act as or with the authority of any such government or local authority including any de facto government or local authority
or by any committee or person having under the terms of the war risks insurance on the Vessel the right to give any such directions or recommendations. If by reason of or in compliance with any such directions or recommendations anything is done or
is not done, such shall not be deemed a deviation. 

 If by reason of or in compliance with any such direction or
recommendation the Vessel does not proceed to any place of discharge to which she has been ordered pursuant to this Charter, the Vessel may proceed to any place which the master or Owner in his or its discretion select and there discharge the cargo
or such part of it as may be affected. Such 

  

					
	Execution version – Hull No. 1688	 	58	 	









 
discharge shall be deemed to be due fulfillment of Owner’s obligations under this Charter so far as the cargo so discharged is concerned; provided, however, that Owner shall use reasonable
endeavors to advise Charterer of the proposed alternative place of discharge and shall, insofar as is practicable in the circumstances, take into consideration any alternative proposal of Charterer. 

Charterer shall procure that all bills of lading issued under this Charter shall contain clauses consistent with Conwartime 2004, and any amendments thereof.

  

	39.	Both to Blame Collision Clause 

 If the liability for any collision in which the Vessel is involved while
performing this Charter fails to be determined in accordance with the laws of the United States of America, the following provision shall apply: 

“If the Vessel comes into collision with another ship as a result of the negligence of the other ship and any act, neglect or default of
the master, mariner, pilot or the servants of the carrier in the navigation or in the management of the ship, the owners of the cargo carried hereunder will indemnify the carrier against all loss or liability to the other or non-carrying ship or her
owners in so far as such loss or liability represents loss of, or damage to, or any claim whatsoever of the owners of the said cargo, paid or payable by the other or non-carrying ship or her owners to the owners of the said cargo and set off,
recouped or recovered by the other or non-carrying ship or her owners as part of their claim against the carrying ship, or carrier.” 

“The foregoing provisions shall also apply where the owners, operators or those in charge of any ship or ships or objects other than, or
in addition to, the colliding ships or objects are at fault in respect of a collision or contact.” 
 Charterer shall procure that all bills of lading
issued under this Charter shall contain a provision in the foregoing terms to be applicable where the liability for any collision in which the Vessel is involved falls to be determined in accordance with the laws of the United States of America.

  

	40.	New Jason Clause 

 General average contributions shall be payable according to the York/Antwerp Rules,
1994, and shall be adjusted in London in accordance with English law and practice, but should adjustment be made in accordance with the law and practice of the United States of America, the following provision shall apply: 

“In the event of accident, danger, damage or disaster before or after the commencement of the voyage, resulting from any cause whatsoever,
whether due to negligence or not, for which, or for the consequence of which, the carrier is not responsible by statute, contract or otherwise, the cargo, shippers, consignees or owners of the cargo shall contribute with the carrier in general
average to the payment of any sacrifices, losses or expenses of a general average nature that may be made or incurred and shall pay salvage and special charges incurred in respect of the cargo.” 

  

					
	Execution version – Hull No. 1688	 	59	 	









 “If a salving ship is owned or operated by the carrier, salvage shall be paid for as fully
as if the said salving ship or ships belonged to strangers. Such deposit as the carrier or his agents may deem sufficient to cover the estimated contribution of the cargo and any salvage and special charges thereon shall, if required, be made by the
cargo, shippers, consignees or owners of the cargo to the carrier before delivery.” 
 Charterer shall procure that all bills of lading issued under
this Charter shall contain a provision in the foregoing terms, to be applicable where adjustment of general average is made in accordance with the laws and practice of the United States of America. 

 

	41.	Clause Paramount 

 Charterer shall procure that all bills of lading issued pursuant to this Charter shall
contain the following clause: 
 “(1) Subject to sub-clause (2) or (3) hereof this bill of lading shall be governed by, and
have effect subject to, the rides contained in the International Convention for the Unification of Certain Rules relating to Bills of Lading signed at Brussels on 25th August 1924 (hereafter the “Hague Rules”) as amended by the
Protocol signed at Brussels on 23rd February 1968 (hereafter the “Hague-Visby Rules”). Nothing herein contained shall be deemed to be either a surrender by the carrier of any of his rights or immunities or an increase of any of his
responsibilities or liabilities under the Hague-Visby Rules.” 
 “(2) If there is governing legislation which applies the Hague
Rules compulsorily to this bill of lading, to the exclusion of the Hague-Visby Rules, then this bill of lading shall have effect subject to the Hague Rules. Nothing herein contained shall be deemed to be either a surrender by the carrier of any of
his rights or immunities or an increase of any of his responsibilities or liabilities under the Hague Rules.” 
 “(3) If there is
governing legislation which applies the United Nations Convention on the Carriage of Goods by Sea 1978 (“Hamburg Rules”) compulsorily to this bill of lading to the exclusion of the Hague-Visby rules, then this bill of lading shall have
effect subject to the Hamburg Rules. Nothing herein contained shall be deemed to be either a surrender by the carrier of any of his rights or immunities or an increase of any of his responsibilities or liabilities under the Hamburg Rules.” 

“(4) If any term of this bill of lading is repugnant to the Hague-Visby Rules, or Hague Rules or Hamburg Rules, if applicable, such term
shall be void to that extent but no further.” 
 “(5) Nothing in this bill of lading shall be construed as in any way restricting,
excluding or waiving the right of any party or person to limit his liability under any available legislation and/or law.” 
  

	42.	Rules and Regulations; Trading; Pollution 

  

	(a)	 In the event of any modifications, changes in specification, structural changes or new equipment (collectively, “Changes”) becoming
compulsory for the continued operation of 



  

					
	Execution version – Hull No. 1688	 	60	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
the Vessel by reason of new class requirements or national or international regulations (including, but not limited to, amendments to the United States Oil Pollution Act, 1990) coming into effect
after the date hereof, Owner shall promptly give Charterer written notice thereof (a “Changes Notice”). The Changes Notice shall state the nature of all Changes covered by the notice as well as the amount and detail of the costs therefor.
Owner shall consult with Charterer regarding the necessity, timing and nature of the work required to effect such Changes. Owner shall use all reasonable efforts to minimize the need for and the cost of Changes. In respect of the costs incurred
pursuant to this Clause 42(a) which are LNG Carrier Changes (as defined below), Charterer shall be responsible for the cost of such LNG Carrier Changes up to an amount equal to the USD *****multiplied by the lesser of: (i) *****and
(ii) *****(the “Charter’s Maximum LNG Carrier Changes”). Owner shall be responsible for any cost of LNG Carrier Changes in excess of Charterer’s Maximum LNG Carrier Changes. Charterer shall be responsible for the full cost
of Changes which are not LNG Carrier Changes. Any costs to be borne by Charterer in accordance with this Clause 42(a) shall be paid, in Charterer’s option, either in cash against presentation of invoices for the relevant modifications or by way
of adjustment to the hire payable hereunder in accordance with Schedule III to this Charter. In this Clause 42(a), “LNG Carrier Changes” means any Changes which apply to the Vessel and which also apply to a conventional LNG carrier which
does not have regasification capability. 

  

	(b)	If the Vessel can continue its service under this Charter, based upon an adjusted trading pattern and voyage planning determined by Charterer in its sole discretion, without the necessity for effecting such Changes,
Charterer shall have the right to continue this Charter without such Changes. 

  

	(c)	If Charterer does not advise Owner in writing of an adjusted trading pattern and voyage planning within ***** days of the Changes Notice, Owner shall proceed with the Changes. 


 

	(d)	Without prejudice to Clauses 14(a) or 24, Charterer accepts any limitations placed at any time during the period of this Charter on trading by the Flag State or the state in which the effective management of the Vessel
is exercised; provided, however, that if any such limitation imposed by the Flag State impairs the ability of the Vessel to conduct the carriage of LNG under this Charter, and if a change in the Vessel’s registration could remove or alleviate
such impairment, then the Vessel’s registration shall be changed to another jurisdiction mutually agreed between Charterer and Owner. The cost of change of flag shall be for Charterer’s account. 


 

	(e)	 Subject to the other provisions of this Clause 42, Owner shall comply with (and shall ensure that the Vessel complies with) all financial capability,
responsibility, security or like laws, regulations and/or other requirements of whatever kind with respect to pollution damage (including compliance with the United States Oil Pollution Act, 1990, as amended or as it may be amended from time to
time, when the Vessel is trading with ports in the United States and, when the Vessel is trading elsewhere, the International Convention on Civil Liability for Oil Pollution, Damage, 1969, as amended by the 1992 Protocol and the 2000 Amendments and
as may be further amended from time to time) in 



  

					
	Execution version – Hull No. 1688	 	61	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
effect on the date of this Charter which are applicable to the Vessel entering, leaving, remaining at or passing through any places or waters in the performance of this Charter. Owner shall make
all arrangements by bond, insurance or otherwise and take all such other action as may be necessary to satisfy such laws, regulations and/or other requirements. All costs and expenses incurred in complying with this Clause 42(e) shall be operating
costs for the purposes of Schedule III. 

  

	43.	Export Restrictions 

 The master shall not be required or bound to sign bills of lading for the carriage
of cargo to any place to which export of such cargo is prohibited under the laws, rules or regulations of the country in which the cargo was produced and/or shipped. 

Charterer shall procure that all bills of lading issued under this Charter shall contain the following clause: 

“If any laws rules or regulations applied by the government of the country in which the cargo was produced and/or shipped, or any relevant
agency thereof, impose a prohibition on export of the cargo to the place of discharge designated in or ordered under this bill of lading, carriers shall be entitled to require cargo owners forthwith to nominate an alternative discharge place for the
discharge of the cargo, or such part of it as may be affected, which alternative place shall not be subject to the prohibition, and carriers shall be entitled to accept orders from cargo owners to proceed to and discharge at such alternative place.
If cargo owners fail to nominate an alternative place within ***** hours after they or their agents have received from carriers notice of such prohibition, carriers shall be at liberty to discharge the cargo, or such part of it as may be affected by
the prohibition, at any safe place on which they or the master may in their or his absolute discretion decide and which is not subject to the prohibition, and such discharge shall constitute due performance of the contract contained in this bill of
lading so far as the cargo so discharged is concerned.” 
 The foregoing provision shall apply mutatis mutandis to this Charter, the references
to a bill of lading being deemed to be references to this Charter. 
  

	44.	Safe Navigation Clause 

 In the interests of safety, Owner will recommend that the master observe the
recommendations as to traffic separation and routing as issued from time to time by the International Maritime Organization and the rules promulgated by the Flag State of the Vessel or the state in which the effective management of the Vessel is
exercised: 
  

	45.	Cargo Management; Filling Level Restrictions 

  

	(a)	 The Vessel shall trade and operate under this Charter at all times, including, without limitation, when the Vessel is connected to the Buoy System
during any Discharge Period, with her cargo tanks loaded in an amount within the tolerances permitted by the Classification Society and within the filling level restrictions stipulated by the guidelines of the Classification Society and GTT for the
Vessel’s safe operation and cargo 



  

					
	Execution version – Hull No. 1688	 	62	 	










	 	
management. In addition, for the duration of any period when the Vessel is connected to the Buoy System, the Vessel shall be operated in accordance with the provisions of paragraph 12 of Appendix
I to Schedule I and the operational limitations relating to tank discharge sequences and cargo re-distribution routines set out in the SRV Operating Manual. Any time lost by reason of the Vessel not being able to remain connected to the Buoy System
and/or to discharge LNG or regasified LNG as a consequence of Owner’s adherence to such guidelines relating to the management of the Vessel’s cargo and filling level restrictions shall count as time on-hire. 


 

	(b)	Owner shall have the right, at any time following an instruction from Charterer, to reject such an instruction if to comply with such instruction would, in the master’s sole discretion, result in a breach of the
limitations specified by either the Classification Society, GTT, the laws or regulations of the Vessel’s Flag State, or the guidelines set forth in the SRV Operating Manual. Any damage to the Vessel’s cargo tanks and their insulation
caused by the Vessel’s non-compliance with the provisions of Clause 45(a), and the time taken to repair such damage, shall be for Owner’s account. 

  

	46.	Boil-off 

 Subject to Clauses 24(g) and 27(c)(ii), Owner shall be entitled to use boil-off from the LNG
being transported at no cost to Owner. Owner shall use reasonable endeavors to minimize boil-off. Charterer may, at its option, require a greater boil-off to be used as fuel (within the capability of the Vessel and subject to considerations of
safety as determined by the master) by so informing the master and Owner. 
  

	47.	Purging and Cool Down 

  

	(a)	Charterer shall provide, without cost to Owner, sufficient LNG to purge and cool down the cargo tanks and other handling systems to the temperature necessary to commence loading, together with a suitable return gas line
to the shore facility upon the arrival of the Vessel at the loading port prior to first loading of the Vessel hereunder and following any scheduled dry docking. The Vessel shall be on-hire during any such purging and cool down operation which shall
be without any cost to Owner. If purging and/or cool down is required for any other reason attributable to Charterer, Charterer shall provide, without cost to Owner, sufficient LNG to purge and/or cool down the cargo tanks and other handling systems
to appropriate temperature as determined by Charterer, and the Vessel shall remain on hire during any such purging and cooling down operation. Charterer shall also provide without charge LNG required for purging and cooling the Regasification
Components as necessary to discharge regasified LNG. 

  

	(b)	If purging and/or cool down in any other circumstances (including unscheduled dry-docking or other exceptional circumstances) is required by Owner (for Owner’s purposes) Charterer shall provide sufficient LNG to
purge and/or cool down the cargo tanks and ether handling systems to appropriate temperatures as determined by Owner, but Owner shall bear the cost and time of such purging/cool down, and shall pay Charterer for any LNG provided at the LNG F.O.B.
price at the loading port. Owner shall be credited for any gas detected as liquid (LNG) at the Vessel’s tank(s) bottom. 


  

					
	Execution version – Hull No. 1688	 	63	 	










	(c)	Owner, the master and Charterer shall agree from time to time based on current experience as to the quantity of LNG to be retained on board following cargo discharge for the purpose of cooling and propulsion on the
ballast voyage so as to permit the Vessel to arrive at the next loading berth in a ready-to-load condition. If no such agreement can be reached, said quantity shall be as established by an independent surveyor knowledgeable in the transportation of
LNG chosen by Charterer in consultation with Owner. Owner and the master shall cooperate with Charterer to manage retained LNG for cargo tank cooling in accordance with Charterer’s reasonable instructions. 


 

	48.	Nitrogen and Inert Gas 

 The supply of inert gas and nitrogen shall be the responsibility of Owner, but
the cost of fuel for same shall be for Charterer’s account. 
  

	49.	Measuring Devices 

 Owner shall equip the Vessel with ullage tables, gauges and devices for measuring
temperature, level and pressure, and gauges and devices suitable for accurately measuring regasified LNG, which are acceptable to governmental authorities and the parties in the trade in which the Vessel is engaged and which are customarily
maintained on board LNG carriers, including SRVs. Such tables, gauges and devices shall be accurate and reliable in their practical application and shall comply with the maximum permissible tolerances provided for in Schedule I. Compliance with the
foregoing shall be certified by an internationally recognized independent marine surveyor chosen by Owner and approved by Charterer. From time to time as requested by Charterer (but not to exceed the period between the Vessel’s normal
dry-dockings for items (i) and (ii) below), in a manner which avoids undue interference with normal operation of the Vessel, Owner shall arrange for: 
  

	 	(i)	testing the accuracy of the instrumentation described above; 

  

	 	(ii)	the recalibration of such instruments; and 

  

	 	(iii)	the recalibration and recertification of tank gauge tables. 

 Such testing and recalibration shall be done
using LNG industry approved methods. All costs incurred in relation to such testing and recalibration under (i), (ii) and (iii) above shall be an operating cost pursuant to Schedule III. 

 

	50.	Sampling and Measuring of Cargo 

 Charterer or its representatives shall have the right to attend
measurements, take samples, and read and record indications from the cargo instrumentation during loading and discharging operations. At Charterer’s request, from time to time, Owner shall ensure that LNG samples are transported on the Vessel
and are properly stored during the voyage and delivered to purchasers and/or suppliers of LNG upon arrival at the termination of the voyage. 

  

					
	Execution version – Hull No. 1688	 	64	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	51.	Drawings, Specifications and Modifications 

  

	(a)	Owner shall provide to Charterer one (1) true copy of each instruction manual and any other plans, drawings, designs and specifications for the Vessel as Charterer shall reasonably request with respect to ship to
shore interface. Owner shall furnish to Charterer full information on the type and accuracy of heel and trim gauges for use with tank calibration tables and of such measuring instruments used for level, temperature and density of LNG as are fitted
on board. 

  

	(b)	After the Delivery Date, Owner shall cause such other changes to be made to the Vessel as Charterer may from time to time reasonably request; provided, however, that Owner shall not be obligated to approve, make or
cause to be made any changes which would conflict with applicable rules or regulations of governmental authorities, the Vessel’s Classification Society, or applicable international organizations, or which in the reasonable opinion of Owner
would affect the ability to comply with its obligations as to performance and maintenance contained in this Charter. All costs incurred as a result of such changes shall be borne by Charterer in accordance with Schedule III. Owner and Charterer
shall consult as to the timing and the nature of the work required. Time taken to pursue any such work shall count as time on-hire hereunder. 

  

	52.	Taxes 

  

	(a)	All payments of hire and other payments made by Charterer to Owner under this Charter shall be made without deduction or withholdings whatsoever in respect of Taxes imposed on such hire or other payment by any country
(or any taxing authority thereof or therein) where loading or discharging of LNG takes place or where the Vessel is located or through which it travels, of where Charterer is organised, does business or has a fixed place of business, or where
Clatterer makes payments under this Charter, unless Charterer is required by applicable law to make any such deduction or withholding, in which event, except as provided in Clause 52(c), the amount payable hereunder in respect of hire shall be
increased by an amount (an “Additional Amount”) so that the amount received by Owner net of such Tax, deduction or withholding shall be the amount that would have been received but for such deduction or withholding. Charterer shall deduct
the legally required amount of withholding Tax and shall pay such Tax over to the relevant taxing authority and shall provide Owner with an original receipt evidencing payment of such Taxes within ***** business days of payment of such Tax.


 All payments made by Owner to Charterer under this Charter shall be made without deduction or withholdings whatsoever in
respect of Taxes imposed on such payment by any country (or any taxing authority thereof or therein) where Owner is organized, does business or has a fixed place of business, or where Owner makes payments under this Charter, unless Owner is required
by applicable law to make any such deduction or withholding, in which event, the amount payable hereunder shall be increased by an amount an (“Additional Amount”) so that the amount received by Charterer net of such Tax, deduction or
withholding shall be the amount that would have been received but for such deduction or withholding. Owner shall deduct the legally required amount of withholding Tax and shall pay such Tax over to the relevant taxing authority and shall provide
Charterer with an original receipt evidencing payment of such Taxes within ***** business days of payment of such Tax. 

  

					
	Execution version – Hull No. 1688	 	65	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(b)	Except as provided in Clause 52(c), if Taxes are imposed on Owner (or any successor or affiliate) or the Vessel in respect of hire under this Charter, Charterer will, on written demand by Owner, indemnify and hold
harmless Owner (or any successor or affiliate) against such Taxes imposed by any country (or any taxing authority thereof or therein) where loading or discharging of LNG takes place or where the Vessel is located or through which it travels, or
where Charterer is organised, does business or has a fixed place of business, or where Charterer makes payments under this Charter. 

  

	(c)	Charterer’s obligations under Clauses 52(a) and (b) are limited by the following: 

  

	 	(i)	Charterer’s obligations relate only to Taxes or withholdings or deductions of Tax in respect of hire earned hereunder, and arise only out of the Vessel’s service under this Charter, not out of or in relation
to any other business activities of Owner unrelated to this Charter in or with respect to the relevant taxing jurisdiction. 

  

	 	(ii)	Charterer shall not be responsible for any Tax that would not be imposed but for Owner’s being organized in or resident of, having a present or former office, principal or fixed place of business or agency
(excluding any office, principal or fixed place of business or agency existing or deemed to exist as a result of Owner’s or Charterer’s activities in connection with the performance of its obligations under this Charter, except for any
office, principal or fixed place of business or agency existing or deemed to exist as a result of or in connection with Owner’s regasification activities contemplated under this Charter) in the jurisdiction imposing the Tax. 


 

	 	(iii)	Charterer shall not be responsible for any Taxes, withholding or deduction imposed by the Vessel’s country of registry to the extent such Taxes are imposed solely as a result of the Vessel being registered in such
country. 

  

	 	(iv)	Charterer shall not be responsible for any Taxes imposed under Section 887 of the Code except if such Tax is imposed as a result of the Vessel being used in a manner that does not constitute the “international
operation of ships” within the meaning of Section 883 of the Code or as a result of Charterer’s failure to meet its obligations under this Charter. 


 

	 	(v)	Charterer shall not be responsible for any Taxes imposed under Section 884 of the Code. 

  

	 	(vi)	 For purposes of this Clause 52(c)(vi), the term “Listed Country” means a country listed on Appendix 1 to Schedule I as the location of a
“Loading Terminal” under Clause 1(a) of such Appendix or “Unloading Terminal” under Clause 1(b) of such Appendix. Charterer shall not be obligated to indemnify Owner for Taxes under this Clause 52 to the extent that such Taxes
are imposed by a Listed Country and such Taxes would not have been imposed had Owner been a tax resident of 



  

					
	Execution version – Hull No. 1688	 	66	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
Norway and had benefited from any of the shipping article, the business profits article, the permanent establishment article, or other relevant provisions of a double tax treaty between Norway
and the Listed Country imposing the Tax, as such treaty is in effect from time to time, except if such Tax is imposed as a result of Charterer’s failure to meet its obligations under this Charter. 


 

	(d)	In case Charterer is obligated to indemnify for Taxes pursuant to Clause 52(b), Owner shall promptly provide Charterer with an accounting of any indemnifiable Taxes payable by the indemnified party and if the
indemnified party shall have paid the Taxes to be indemnified shall provide Charterer with a copy of accurate official receipts from the appropriate governmental or taxing authority, if available, or other documents showing the amount of the above
Taxes paid by Owner. 

  

	(e)	Owner shall use all reasonable efforts to reduce or avoid withholdings and deductions which would otherwise become the obligation of Charterer hereunder. 


 

	(f)	Taxes indemnified hereunder shall be paid within ***** business days of demand by Owner. 

  

	53.	Law and Arbitration 

 This Charter shall be construed and the relations between the parties determined in
accordance with the laws of England. The foregoing notwithstanding, no term of this Charter is enforceable under the Contracts (Rights of Third Parties) Act 1999 by a person who is not a party to it. 

All disputes or differences arising out of or under this Charter which cannot be amicably resolved shall be referred to arbitration in London. 

Unless the parties agree upon a sole arbitrator within ***** days of one party requiring the other to do so, each party shall appoint its own arbitrator. The
arbitrators so appointed shall appoint a third arbitrator and the reference of any such dispute shall be to the 3-man tribunal thus constituted. 
 If
either of the appointed arbitrators refuses to act or is incapable of acting, the party who appointed him shall appoint a new arbitrator in his place. 
 If
one party fails to appoint an arbitrator, whether originally or by way of substitution, within ***** weeks after the other party has appointed his arbitrator, and such other party has (by telex, fax or letter) called upon the defaulting party to
make the appointment, the President for the time being of the International Chamber of Commerce (“ICC”) shall, upon application of the other party, appoint an arbitrator on behalf of the defaulting party and that arbitrator shall have the
like powers to act in the reference and make an award (and, if the case so requires, the like duty in relation to the appointment of a third arbitrator) as if he had been appointed by the defaulting party in accordance with the terms of this
Charter. 
 The ICC Rules of Arbitration (the “ICC Rules”) in force at the time when the arbitration proceedings are commenced shall apply to any
arbitration arising in connection with this Charter; provided, however, that where the amount in dispute does not exceed the sum of ***** United States Dollars (US$*****) (or such other sum as the parties may agree) any dispute shall be resolved in
accordance with the Guidelines for Arbitrating Small Claims under the ICC Rules. 

  

					
	Execution version – Hull No. 1688	 	67	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	54.	Construction 

 The headings have been included in this Charter for convenience of reference and shall in
no way affect the construction hereof. 
  

	55.	Custody Transfer and Calibration/Tank Tables 

 The cargo quantity measurement for custody transfer
purposes, irrespective of whether the Vessel operates, and discharges LNG, as a conventional LNG carrier or whether the Vessel operates, and discharges regasified LNG, as an SRV, shall be based on measurements and sampling using the Vessel’s
LNG cargo tank level measuring equipment (using the “ship figures in/out” principle). 
 Owner shall cooperate with Charterer in matters relating
to and arising out of written requirements and procedures of Charterer for the sampling and measuring of cargo and the testing of the Vessel’s custody transfer equipment. Owner shall permit Charterer or its representatives or its affiliates to
be present at the time when the custody transfer is taking place and at a time when the LNG cargo tanks are routinely inspected and calibration checks are made to the custody transfer equipment. In the event that any of the Vessel’s custody
transfer equipment is found to be incorrect or if the accuracy of any parts fails to meet the applicable tolerances as provided in Schedule I, then Owner shall take all necessary steps, as soon as may be convenient to Charterer, to remedy the
incorrectness or inaccuracy to the satisfaction of an approved measurer, the cost of recalibration of cargo tanks and the cost of necessary repairs to custody transfer equipment shall be an operating cost forming part of the Variable Element under
Schedule III. 
 If the validity of the tank tables is reasonably questioned, Charterer may require recalibration of the LNG tank or tanks which shall
be carried out during routine dry-docking or during a repair period of sufficient duration or sooner if Charterer so requests and Owner consents, such consent not to be unreasonably withheld, conditioned or delayed. If the tank tables are found to
be incorrect by more or less than ***** of one percent (*****%), then the time and cost of such recalibration shall be for Owner’s account, but if not, the time lost and any costs shall be borne by Charterer. 

 

	56.	Drug and Alcohol Clause 

 Owner warrants that they have a policy on drug and alcohol abuse applicable to
the Vessel which meets or exceeds the standards in the Oil Companies International Marine Forum Guidelines for the Control of Drugs and Alcohol Onboard Ship (the “Policy”). Under the Policy, alcohol impairment shall be defined as a blood
alcohol content of 40mg/100ml or greater, the appropriate seafarers to be tested shall be the Vessel’s officers and the drug/alcohol testing and screening shall include unannounced testing in addition to periodic testing. An objective of the
Policy should be that the frequency of the unannounced testing be adequate to act as an effective abuse deterrent, and that all officers be tested at least once a year through a combined program of unannounced testing and routine medical
examinations. 

  

					
	Execution version – Hull No. 1688	 	68	 	









 Owner further warrants that the Policy will remain in effect during the term of this Charter and that Owner shall
exercise due diligence to ensure that the Policy is complied with. It is understood that an actual impairment or any test finding of impairment shall not in and of itself mean Owner has failed to exercise due diligence. 

 

	57.	Pollution and Emergency Response 

 Owner shall advise Charterer of organizational details and names of
Owner’s personnel together with their relevant email addresses and telephone/facsimile numbers, including the names and contact details of qualified individuals who may be contacted on a 24-hour basis in the event of bunker spills or other
emergencies as required by the U.S. Oil Pollution Act 1990. 
  

	58.	ISPS Code; Maritime Transportation Security Act 

 This Clause 58 makes reference to the International
Ship and Port Facility Security Code and the relevant amendments to Chapter XI of SOLAS (the “ISPS Code”) and the US Maritime Transportation Security Act 2002 (the “MTSA”). 

 

					
	(a)	  	(i)	  	At all times during the Term of this Charter, Owner shall procure that the Vessel, “the Company” (as defined by the ISPS Code) and the “owner” (as defined in the MTSA) (together with Owner, the “Responsible
Parties”) shall comply with the requirements of the ISPS Code and the MTSA relating to the Responsible Parties. Upon request, Owner shall provide documentary evidence of compliance with this Clause 58(a)(i).
			
		  	(ii)	  	Except as otherwise provided in this Charter, loss, damage, expense or delay caused by failure on the part of the Responsible Parties to comply with the requirements of the ISPS Code, the MTSA or this Clause 58 shall be for
Owner’s account.
			
	(b)	  	(i)	  	 Charterer shall provide Owner and the Vessel’s master with its full style contact details and shall ensure that the contact details of
all sub-charterers, if any, are likewise provided to Owner and the Vessel’s master. Furthermore, Charterer shall ensure that any sub-charter it enters into during the Term of this Charter contains the following provision:

 
 “Charterer shall provide Owner with its full style contact details and, where
sub-letting is permitted under the terms hereof, shall ensure that the contact details of all sub-charterers are likewise provided to Owner.”

			
		  	(ii)	  	Except as otherwise provided in this Charter, loss, damage, expense or delay caused by failure on the part of Charterer to comply with this Clause 58(b) shall be for Charterer’s account.

  

	(c)	 Notwithstanding anything else contained in this Charter, costs or expenses related to security regulations or measures required by the port facility
or any relevant authority in accordance with the ISPS Code and/or the MTSA including, but not limited to, security guards, launch services, tug escorts, port security fees or taxes and inspections, shall be




  

					
	Execution version – Hull No. 1688	 	69	 	










	 	
for Charterer’s account, unless such costs or expenses result solely from Owner’s negligent act or omission, in which case such costs or expenses shall be for Owner’s account. All
measures required by Owner to comply with the security plan required by the ISPS Code and the MTSA shall be for Owner’s account. 

  

	(d)	Notwithstanding any other provision of this Charter, the Vessel shall not be off-hire where there is a loss of time caused by Charterers’ failure to comply with the ISPS Code or the MTSA. 


 

	(e)	If either party makes any payment which is for the other party’s account according to this Clause 58, the other party shall indemnify the paying party. 


 

	59.	Temperature of Tanks on Arrival at Loading Port 

 In the event that the arrival temperature of the cargo
tanks is higher than specified in Schedule I for any reason other than one causing the Vessel to be off-hire pursuant to Clause 24, the extra time and LNG required to cool the cargo tanks shall be for Charterer’s account. 

 

	60.	Notices 

  

	(a)	Whenever written notices are required to be given by either party to the other party, such notices shall be sent by registered mail, courier, telex or telefax or delivered by hand to the following addresses:


 Notice to Charterer: 

SUEZ LNG TRADING SA 
 76 avenue
de la Liberté 
 L-1930 Luxembourg, 

Grand Duché de Luxembourg 

Fax: +352 264 843 13 
 Attn:
Managing Director 
 With a copy to: 

Suez Global LNG Ltd. 
 101
Wigmore Street, 3rd Floor 
 London W1U 1QU (United Kingdom) 

Fax: +44 207 915 3911 
 Attn:
Senior VP – Shipping and Operations 
 Email: operations@suezlng.com 

Notice to Owner: 
 SRV JOINT GAS
LIMITED 
 c/o Höegh LNG AS 

Drammensveien 134 
 P.O. Box 4
Skoyen 
 0212 Oslo, Norway 

Fax: +47 21039013 
 Attn:
Executive Vice-President 
 Email: hlng@hoegh.com 

  

					
	Execution version – Hull No. 1688	 	70	 	









 With a copy to: 

Mitsui O.S.K. Lines, Ltd. 
 1-1,
Toranomon 2-Chome, Minato-ku 
 Tokyo 105-8688, Japan 

Fax: +81-3-3587-7737 
 Attn:
General Manager, LNG Carrier Division 
 Email: lgcmo@mail.mol.co.jp 

or to such other addresses as the parties may respectively from time to time designate by notice in writing. Any failure to transmit a copy of
the notice to a party listed as entitled to receive a copy shall not in any way affect the validity of any notice otherwise properly given as provided in this Clause 60. 
  

	(b)	Any notice required under this Charter to be given in writing shall be deemed to be duly received only: 

  

	 	(i)	In the case of a telex, at the time of transmission recorded on the message if such time is within normal business hours between 9:00 a.m. and 5:00 p.m. on a working day at the place of receipt, otherwise at the
commencement of normal business hours on the next working day at the place of receipt, subject in both cases to an acknowledgment being received by automatic telex answer back response. 


 

	 	(ii)	In the case of a letter, whether delivered in course of the post or by hand or by courier, at the date and time of its actual delivery if within normal business hours between 9:00 a.m. and 5:00 p.m. on a working day at
the place of receipt, otherwise at the commencement of normal business on the next working day. 

  

	 	(iii)	In the case of a telefax, at the time of transmission recorded on the message if such time is within normal business hours between 9:00 a.m. and 5:00 p.m. on a working day at the place of receipt, otherwise at the
commencement of normal business hours on the next working day at the place of receipt, subject in both cases to an acknowledgment being received by telefax. 

  

	61.	Non-Waiver 

 No act, omission, course of dealing, forbearance, indulgence, approval or delay by Owner or
Charterer in exercising their rights hereunder (whether pursuant to any default of the other party or otherwise), or in enforcing any of the terms or conditions of this Charter, nor any granting of 

  

					
	Execution version – Hull No. 1688	 	71	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 
time, shall prejudice or affect or be in derogation of the rights and remedies of such party hereunder and no such matter shall be treated as evidence, or constitute a waiver, of any rights of
Owner or Charterer as the case may be. 
  

	62.	Prior Agreements 

 From the date of effectiveness, this Charter together with the Charter for Vessel Hull
Number 1689 and the agreement regarding the option for a third vessel executed by the Parties contemporaneously with this Charter comprises the full and complete agreement of the parties with respect to the shipping arrangements between the parties
(and Neptune LNG LLC) and supersedes all prior communications, understandings and agreements between the parties (and Neptune LNG LLC), whether written or oral, expressed or implied, with regard to said subject matter. 

 

	63.	Consequential Damages 

 Notwithstanding any other provisions of this Charter, neither Charterer nor Owner
shall be liable, one against the other, for any consequential, punitive or special damages arising out of, or in any way connected to, the performance of this Charter, including without limitation loss of profit, earnings, use or production and in
respect of compensation for any liabilities or damages incurred by either Charterer or Owner to third parties; provided, however, that for the purposes of this Clause 63, consequential damages shall not include any provisions in this Charter which
provide for payments of money. 
  

	64.	Commissions 

 Charterer represents and warrants that there are no commissions or brokers’ fees
payable by Charterer in connection with this Charter. Owner represents and warrants that there are no commissions or brokers’ fees payable by Owner in connection with this Charter. 

 

	65.	Owner’s Default 

 In the event that any of the following shall occur: 

 

	(a)	Owner suspends payment of its debts or is unable to pay its debts; 

  

	(b)	Owner passes a resolution, commences proceedings or has proceedings commenced against them (which are not stayed within ***** days of service thereof on Owner) in the nature of bankruptcy, composition, arrangement,
reorganization, a general assignment for the benefit of their creditors or other scheme resulting from insolvency or for its liquidation or for the appointment of a receiver, trustee in bankruptcy or liquidator; 


 

	(c)	Owner’s Guarantee ceases to be in full force and effect (unless, within ***** days thereafter, a replacement guarantee equal in value to Owner’s Guarantee and given by a person or entity acceptable to
Charterer is substituted for Owner’s Guarantee no longer in effect); or 

  

	(d)	Guarantor takes or suffers to be taken against it any of the actions set forth in (a) or (b) above; 


  

					
	Execution version – Hull No. 1688	 	72	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 then, unless any of the above are caused by a failure of Charterer to pay hire when due, Charterer may, at
its absolute discretion, terminate this Charter, whereupon Owner shall immediately reimburse Charterer for any hire paid and not earned and any other sums to which Charterer is entitled under this Charter and, without prejudice to any other right or
claim Charterer may have against Owner, Charterer may, at its option, which shall be exercised upon notice to Owner given not less than ***** days prior to the date Charterer desires the bareboat charter to become effective, convert the Charter into
a bareboat charter and operate the Vessel instead at its sole risk and for its own account. If Charterer exercises its option to bareboat charter the Vessel, then the bareboat charter shall be based on the BARECON 2001 form of charterparty under
terms substantially similar, mutatis mutandis, to those in this Charter and for a team commencing as of the date and time the Vessel is delivered to Charterer or its designee under the bareboat charter and continuing for a period equal to the
then unexpired portion of the Term, and Charterer may appoint a manager of its own choice (subject to such manager having personnel experienced in the operation of LNG carriers). Charterer shall be required to pay hire under such bareboat charter at
a daily rate equal to the Fixed Element. 
  

	66.	Specific Performance 

 Owner acknowledges and agrees that the Vessel, given its operation as an SRV,
constitutes a unique property, that damages for Owner’s breach of contract would be difficult or impossible to ascertain, that Charterer has no clear and adequate remedy at law and that as a remedy for Owner’s breach Charterer has, to the
extent permitted by law or equity, the right (exercisable in its sole discretion) to demand and obtain specific performance of this Charter. As part of pursuing such remedy of specific performance Charterer may pursue such other remedies as
Charterer may have under the terms of this Charter or in equity. The foregoing is subject to the following: 
  

	(a)	nothing in this Clause 66 shall reduce the burden of proof necessary for Charterer to establish a breach of this Charter by Owner; 

  

	(b)	any order for specific performance shall, to the extent permitted by law or equity, be subject to and give effect to the Consent & Agreement; and 


 

	(c)	for the avoidance of doubt, no damages shall be granted in respect of breaches of this Charter for which specific performance has been granted. 


 

	67.	Charterer’s Default 

 In the event that either of the following shall occur: 

 

	(a)	Charterer suspends payment of its debts or is unable to pay its debts; or 

  

	(b)	Charterer passes a resolution, commences proceedings or has proceedings commenced against it (which are not stayed within ***** days of service thereof on Charterer) in the nature of bankruptcy, composition,
arrangement, reorganization, a general assignment for the benefit of its creditors or other scheme resulting from insolvency or for its liquidation or for the appointment of a receiver, trustee in bankruptcy or liquidator; 


  

					
	Execution version – Hull No. 1688	 	73	 	









 then, unless any of the above are caused by a failure of Owner to perform fully its obligations under this
Charter, Owner may, at its absolute discretion, terminate this Charter without prejudice to any other rights Owner may have under this Charter or otherwise. 
  

	68.	Liability & Indemnity 

  

	(a)	Owner shall be under no liability whatsoever to Charterer, Charterer’s Representatives or their estates (“Charterer’s Group”) for their death or personal injury during the time when they are engaged
in the activities contemplated under this Charter unless death or personal injury is caused, in whole or in part, by the gross negligence or willful misconduct of Owner, its employees or its agents (“Owner’s Group”). Owner shall,
likewise, be under no liability to any member of Charterer’s Group in respect of damage to, or loss or destruction of, their personal property unless such damage to, or loss or destruction of, personal property is caused by the gross negligence
or willful misconduct of any member of Owner’s Group. 

  

	(b)	Charterer shall be under no liability whatsoever to any member of Owner’s Group for their death or personal injury during the time when they are engaged in the activities contemplated under this Charter unless
death or personal injury is caused, in whole or in part, by the gross negligence or willful misconduct of a member of Charterer’s Group. Charterer shall, likewise, be under no liability to any member of Owner’s Group in respect of damage
to, or loss or destruction of, their personal property unless such damage to, or loss or destruction of, personal property is caused by the gross negligence or willful misconduct of any member of Charterer’s Group. 


 

	(c)	Charterer shall indemnify and hold harmless any member of Owner’s Group in respect of the claims and liabilities set forth in Clause 68(a) except in respect of such claims and liabilities arising from death or
personal injury, or in respect of damage to, or loss or destruction of the personal property of, any member of Charterer’s Group caused, in whole or in part, by the gross negligence or willful misconduct of such member of Owner’s Group and
Owner shall indemnify and hold harmless any member of Charterer’s Group in respect of the claims and liabilities set forth in Clause 68(b) except in respect of such claims and liabilities arising from death or personal injury, or in respect of
damage to, or loss or destruction of the personal property of, any member of Owner’s Group caused, in whole or in part, by the gross negligence or willful misconduct of such member of Charterer’s Group. 


 

	69.	Corporate Guarantees 

 Simultaneously with the execution of this Charter Höegh LNG Ltd. and Mitsui
O.S.K. Lines, Ltd. (the “Owner’s Guarantors”) have guaranteed the performance by Owner of Owner’s obligations under this Charter by a guarantee in the form set out in Schedule XI (the “Owner’s Guarantee”), provided
that any payment liability of the Owner’s Guarantors under the Owner’s Guarantee shall be several and proportionate to their respective beneficial ownership share of Owner, but the guarantee of performance shall be joint and several. 

  

					
	Execution version – Hull No. 1688	 	74	 	










	70.	Confidentiality 

 The parties agree to keep the terms and conditions of this Charter (the
“Confidential Information”) strictly confidential; provided, however, that a party may disclose Confidential Information in the following cases: 
  

	(a)	It is already known to the public or becomes available to the public other than through the act or omission of the disclosing party; 


 

	(b)	It is required to be disclosed under applicable law or by a governmental order, decree, regulation or rule (provided that the disclosing party shall give written notice of such required disclosure to the other party
prior to the disclosure); 

  

	(c)	In filings with a court or arbitral body in proceedings in which the Confidential Information is relevant and in discovery arising out of such proceedings; or 


 

	(d)	To any of the following persons on a need to know basis: 

  

	 	(i)	a buyer or seller or a potential buyer or seller of LNG shipped or to be shipped on the Vessel; 

  

	 	(ii)	an Affiliated Company; 

  

	 	(iii)	employees, officers, directors and agents of the disclosing party or an Affiliated Company; 

  

	 	(iv)	professional consultants retained by a disclosing party; or 

  

	 	(v)	financial institutions advising on, providing or considering the provision of financing to the disclosing party or an Affiliated Company; 


provided, however, that the disclosing party shall exercise due diligence to ensure that no such person shall disclose Confidential Information to any
unauthorized person or under any unauthorized circumstances. As used in this Clause 70, “Affiliated Company” means (A) a manager of the Vessel under Clause 3(c), (B) any person who directly or indirectly controls, is under common
control with or is controlled by a party to this Charter, and (C) any person who is a shareholder (directly or indirectly) of a party to this Charter. For purposes of this Clause 70, “control” means the right to exercise more than
fifty percent (50%) of the voting rights of the applicable person. 
  

	71.	Intellectual Property 

 Notwithstanding any provisions of Clause 71 below, the rights outlined by the
parties shall in no manner affect the intellectual property rights that any third parties may have to the SRV or Regasification Technology. 

  

					
	Execution version – Hull No. 1688	 	75	 	










	(a)	Each party to this Charter (including any of such party’s Affiliated Companies) shall retain its ownership rights in all intellectual property that it may have shared with the other party as of the date of any
termination of this Charter. For the avoidance of doubt: 

  

	 	(i)	each party shall own its intellectual property independently developed hereunder, and 

  

	 	(ii)	neither party shall act solely to obtain a patent for or purport to license any idea, design, drawing, or concept that addresses, relates to or incorporates any intellectual property received from the other party.


  

	(b)	Notwithstanding any provision of Clause 71(a) above, and for the avoidance of doubt, the parties agree that each party (including any such party’s Affiliated Companies) shall independently have the right to use,
employ, apply, incorporate and otherwise utilize the Regasification Technology for any use whatsoever, including, but not limited to, any other project involving regasification of LNG at any location throughout the world; provided, that neither
party shall act solely to obtain a patent for or purport to license the Regasification Technology. 

  

	(c)	Owner hereby grants to Charterer a world-wide, royalty-free license to use the SRV Technology as related to and implemented on the Vessel during the Term of this Charter. 


 

	(d)	Owner shall defend and indemnify Charterer against any and all claims (including any costs and expenses of investigation or litigation, and further including any attorneys’ fees) by any third party who alleges that
the construction or operation of the Vessel infringes any right claimed by the third party, including but not limited to patent rights, copyrights, trade secrets, industrial property, or trademarks. For purposes of Clause 24(a)(v), any
third-party claim alleging an infringement of any right regarding the SRV Technology shall not be deemed the responsibility of, or the result of any action or inaction of, Charterer. 


 

	(e)	Notwithstanding anything to the contrary in this Clause 71 the provisions of this Clause 71 do not directly or indirectly limit or restrict the. Charterer’s right to enter into arrangements with third parties for
the charter, construction, use, purchase or employment of vessels of the same, or similar type as the SRV or any other on-board regasification vessel. In the event Charterer enters into any such arrangements with any third party, Owner shall not
initiate claims or legal actions against Charterer or third parties which shall have the effect to restrict directly or indirectly Charterer’s aforesaid rights. However, Charterer acknowledges the obligations of Owner under Article XVII,
paragraph 2 of the Building Contract and Charterer agrees not to take any action, or require Owner to take any action, which would put Owner in breach of its said obligations. Charterer shall indemnify and hold harmless Owner for all amounts
properly payable to the Builder, costs and expenses arising from any breach by Charterer of its obligations under the previous sentence. 


  

					
	Execution version – Hull No. 1688	 	76	 	










	72.	Buoy System; Port Liability 

 Owner acknowledges that Charterer, as owner of the Buoy System, may from
time to time permit other regasification vessels other than vessels in the SRV Fleet to call at the Buoy System. As such, the Buoy System will be operated much like a shore-based regasification terminal with the possibility of third-party vessels
calling thereat. In order to ensure an appropriate allocation of liability in the event of a casualty involving Owner, Charterer and/or a third-party vessel occurring at the Buoy System, Owner and Charterer shall execute a port liability agreement,
the terms of which shall reasonably comport with those of other port liability agreements in use at major LNG import and export facilities and those acceptable to internationally recognized protection and indemnity associations. The incremental
insurance cost, if any, incurred as a result of entering any such port liability agreement shall be borne in accordance with Clause 2(c) of Schedule IV. Charterer shall cause all third-party vessels calling at the Buoy System to execute such port
liability agreement. 
  

	73.	Position Reporting System 

 Owner shall permit Charterer to access and utilize the “Purple
Finder” position reporting system, provided that the system and its operation shall not adversely impact the safe operation of the Vessel. 
  

	74.	Safety Management 

  

	(a)	Owner shall operate: 

  

	 	(i)	a safety management system certified to comply with the International Safety Management Code (“ISM Code”) for the Safe Operation of Ships and for Pollution Prevention; 


 

	 	(ii)	a documented safe working procedures system (including procedures for the identification and mitigation of risks); 

  

	 	(iii)	a documented environmental management system; and 

  

	 	(iv)	a documented accident/incident reporting system compliant with flag state requirements. 

  

	(b)	Owner shall submit to Charterer a monthly written report detailing all accidents/incidents (including casualties suffered by her crew and any other personnel on board) and environmental reporting requirements, and in
regard to maintenance of and repairs to the Vessel. 

  

	(c)	Owner shall maintain Health Safety Environmental (“HSE”) records sufficient to demonstrate compliance with the requirements of Owner’s HSE system and of this Charter and Charterer reserves the right to
confirm compliance with HSE requirements by audit of Owner. 

  

	(d)	Owner shall arrange, at its expense, for a SIRE inspection to be carried out as required by the Vessel’s trade. 


  

					
	Execution version – Hull No. 1688	 	77	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	75.	Models 

 Owner shall promptly provide to Charterer two (2) models of the Vessel. 

 

	76.	Conditions Precedent 

 The execution and delivery of this Charter notwithstanding, it shall be a
condition precedent to the effectiveness of this Charter that Owner has received from Charterer, not later than 28 March 2007, a written notice in the form of Schedule XI indicating that Charterer has received all corporate approvals necessary
to make this Charter effective. 
  

	77.	Confirmation of Execution and Delivery 

 Not later than ***** days following the execution and delivery
of this Charter by Owner and Charterer, Owner shall send to Builder (with a copy to Charterer) a written notice confirming same. 

  

					
	Execution version – Hull No. 1688	 	78	 	









 IN WITNESS WHEREOF the parties have executed this Charter in triplicate as of the date above first written. 

 

							
	For and on behalf of Charterer:	 		 	Witness
			
	 /s/ IGNACE BRAECKMAN
	 		 	 /s/ H. BENKATBACH

	Name:	 	Ignace Braeckman	 		 	H. Benkatbach
	Title:	 	Director	 		 	
			
	For and on behalf of Charterer:	 		 	Witness
			
	 /s/ JAN BRACKENIER
	 		 	 /s/ H. BENKATBACH

	Name:	 	Brackenier Jan	 		 	H. Benkatbach
	Title:	 	Director	 		 	
			
	For and on behalf of Owner:	 		 	Witness
			
	 /s/ SVEINUNG STØHLE
	 		 	 /s/ Ø. BRUNO LARSEN

	Name:	 	Sveinung Støhle	 		 	Ø. Bruno Larsen
	Title:	 	Director	 		 	
			
	For and on behalf of Owner:	 		 	Witness
			
	 /s/ TAKESHI HASHIMITO
	 		 	 /s/ KENSUKE TANAKA

	Name:	 	Takeshi Hashimito	 		 	Kensuke Tanaka
	Title:	 	Director	 		 	


  

					
	Execution version – Hull No. 1688	 	79	 	









 SCHEDULE I 

TO SRV LNG TIME CHARTER PARTY 

DATED MARCH 2007 

MAIN PARTICULARS OF VESSEL / GAS FORM C 

The below Information shall be verified throughout the construction phase of the Vessel. 

 

	1.1	PREAMBLE 

  

			
	Ship’s name	  	 [TBN]

		
	Owner	  	 SRV Joint Gas Limited

		
	Flag – Registry	  	 NIS

		
	Builder	  	 Samsung Heavy Industries Co, Ltd, Korea

		
	Delivery	  	 30 October 2009

		
	Class	  	 X1A1 Tanker for Liquefied gas, ship type 2G (Membrane tank, Maximum pressure 25 kPaG, minimum temperature
- 163°C), NAUTICUS (New building) PLUS-2, CSA-2, CLEAN, E0, F-AMC, ICS, TMON, TYNPOS-AUT, STL, BIS, NAUT-AW


  

			
	 GRT/NRT

	International	  	97,100
	Suez	  	[_TBN_]

  

			
	 Is vessel approved?

	USCG	  	[_TBN_]
	IMO	  	[_TBN_]

  

	1.2	HULL 

  

					
	 	  	 Meters
	  	 Feet

	 LOA
	  	280.00	  	918.64
	 LBP
	  	270.00	  	885.83
	 Breadth
	  	43.40	  	142.39
	 Depth
	  	26.00	  	85.30
	 Keel to highest point
	  	55.3	  	181.4
	 Air draught (folded mast)
	  	40.4	  	132.5
	 Assumed ballast draught
	  	9.6	  	31.5


  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 1	 	










							
	Summer Load Line	  	12.4 m	  	Corresponding deadweight	  	80,600 mt
	TPC at design draft 11.4 m	  	100.3 mt/cm

  

					
	 Mean draft with full bunkers and full cargo

	 Specific Gravity
	  	 Mean draft
	  	 Corresponding DW

	0.47 mt/m^3	  	11.64m	  	73,143 mt

  

			
	 Communication equipment

	International call sign	  	[_TBN_]
	Radio station	  	[_TBN_]
	Satcom B	  	[_TBN_]
	 - Telephone/telex
	  	[_TBN_]
	 - Telefax
	  	[_TBN_]
	Satcom C Telex	  	[_TBN_]

  

	1.3	MACHINERY 

  

			
	 Main Engine

	Type	  	 Wartsila: 121.50DF x 3 units
  

Wartsila: 6L50DF x 1 unit

		
	Max Cont.	  	3 x 11,400 kW + 1 x 5,700 kW
		
	Grade fuel used	  	 Marine diesel oil (ISO 8217:1996, DMB),

 
 Boil-off gas

 
 Heavy Fuel Oil: [TBN]



  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 2	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


			
	 Other Machinery

		
	Propeller	  	1 Fixed Pitch,
		
	Bow Thrusters	  	 2,000 kW x 2 units
  

6.6 kV, Controllable Pitch, 4-bladed, Ni-Al-Bronze

		
	Stern Thrusters	  	 1,200 kW x 2 units
  

6.6 kV, Controllable Pitch, 4-bladed, Ni-Al-Bronze.


  

			
	 Speed/Consumption (propulsion power only)

		
	Guaranteed speed (Round trip, Beaufort Force 5)	  	19.5 knots
		
	Average Consumption on guaranteed speed	  	 ***** tons MDO/day (main engine)
  

***** tons HFO/day (main engine)


  

															
	 Fuel consumption (for information only)

	Loading	  	***** tons/day
	Discharging (conventional):	  	***** tons/day
	Anchorage (MDO mode):	  	***** tons/day
	
	 Fuel consumption during regasified LNG discharge (for information
only)

	Regas rate (mmscuf/hr)	  	120	  	250	  	450	  	500	  	600	  	712.5	  	750
	Regas rate (mt/hr)	  	101	  	210	  	378	  	420	  	504	  	599	  	630
	Fuel consumption, NG	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****
	Fuel consumption, MDO (mt/day)	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****

 Note: 
 Gas consumption at DF
engine(s) and 2 regas boilers based on Low Calorific Value (LCV) of 49,900 KJ/kg 
 Diesel oil consumption as pilot fuel at DF engine(s) based on Low
Calorific Value (LCV) of 42,700 KJ/kg. 

  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 3	 	










							
	 Permanent bunkers capacity

	HFO	  	4,360 m^3	  	MDO/MGO	  	1,480 m^3
		  		  	TOTAL	  	5,840 M^3

  

	1.4	CARGO INSTALLATION 

  

																													
	 Transportable products and respective quantities *)
	 
	 Tank No.
	  	20°C
100%
M3	 	  	-163°C
98.5%
M3	 	  	-163°C
98.5%
MT
S.G. 0.47	 	  	-163°C
70%L
M3	 	  	-163°C
70%H
M3	 	  	-163°C
10%L
M3	 	  	-163°C
10%H
M3	 
	 1
	  	 	19,386	  	  	 	19,095	  	  	 	8,975	  	  	 	12,196	  	  	 	13,195	  	  	 	1,398	  	  	 	1,494	  
	 2
	  	 	41,873	  	  	 	41,245	  	  	 	19,385	  	  	 	41,873	  	  	 	31,203	  	  	 	6,541	  	  	 	3,955	  
	 3
	  	 	41,873	  	  	 	41,245	  	  	 	19,385	  	  	 	41,873	  	  	 	31,203	  	  	 	6,541	  	  	 	3,955	  
	 4
	  	 	41,873	  	  	 	41,245	  	  	 	19,385	  	  	 	41,873	  	  	 	31,203	  	  	 	6,541	  	  	 	3,955	  
		  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 
	 Total
	  	 	145,004	  	  	 	142,829	  	  	 	67,130	  	  	 	137,814	  	  	 	106.804	  	  	 	21,022	  	  	 	13,359	  
		  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 	  	  
	  
	 

  

	*)	Approx. figures per 5 April 2006 based on a cargo specific gravity of 470 kg/m^3 

 The cargo tank
system is GTT Mark III, reinforced to all cargo tank area except tank bottom in accordance with GTT document N500 CR009. 
  

	
	Scantlings of the cargo tanks are based on a maximum density of cargo of 500 kg/m3.

  

			
	 Tank working pressure

	Maximum pressure	  	25 kPa gauge
	Minimum pressure	  	1 kPa gauge
	Minimum temperature acceptable in tanks	  	-163°C

  

			
	 Acceptable cargo filling levels

	Lower criteria	  	Below 10% of cargo tank length
	Upper criteria	  	Above 70% of cargo tank height


  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 4	 	










			
	Leading & discharging time for LNG	  	12 hours, excluding time for connecting, disconnecting, cooling down, topping up and custody transfer measurement

  

															
	 Discharging time for regasified LNG

	Regas rate (mmscuf/hr)	  	120	  	250	  	450	  	500	  	600	  	712.5	  	750
	Regas rate (mt/hr)	  	101	  	210	  	378	  	420	  	504	  	599	  	630
	Regas duration (days)	  	26.0	  	12.5	  	7.0	  	6.3	  	5.2	  	4.4	  	4.2

  

	1.5	CARGO MACHINERY 

  

			
	Cargo pumps	  	1,700 m^3/h @155 mlc x 8 units
		
	Cargo pump location	  	2 in each cargo tank
		
	Max permissible specific gravity	  	500 kg/m
		
	Time for discharging full cargo using all cargo pumps against no backpressure	  	12 hours, excluding time for connecting, disconnecting, cooling down, topping up and custody transfer measurement.
		
	Unpumpable cargo volume	  	1,450 m^3
		
	Heel LNG for cooling down	  	500 m^3
		
	Fuel LNG for ballast voyage	  	3,300 m^3
		
	Cargo remaining onboard in cargo tanks after completion pumping	  	5,250 m^3
		
	Spray pumps	  	50m^3/h @145 mlc x 4 units
		
	Emergency cargo pump/ LNG Feed Pump	  	 650m^3/h @145 mlc x 3 units
  

Located in tank No. 2, 3 and 4



  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 5	 	










			
	High duty cargo compressor	  	32,000 m^3/h x 2 units
	Low duty cargo compressor	  	3,000 m^3/h x 2 units
	Nitrogen plant	  	120 Nm^3 x 2 units
	Inert gas plant	  	14,000 Nm^3/h x 1 unit

  

			
	 Composition of inert gas

	Carbon dioxide, CO2	  	Max 14% by volume
	Oxygen max., O2	  	1.0% by volume
	Carbon monoxide max.; CO	  	100 ppm
	HC	  	0%
	Soot	  	Bacharach 0
	Sulphur oxides max., Sox	  	10 ppm
	Nitrogen oxides max.; NOx	  	100 ppm
	Remainder	  	N2, H2, Air
	Dewpoint	  	-45°C at atm.
	Grade fuel used	  	DMA: ISO 8217
	Discharge pressure	  	Max. 25 kPaG

  

			
	State if any shore supply of liquid nitrogen may be required     NO
	May be required for purging of tanks and insulation spaces	  	
	What quantity?	  	0

  

			
	 Gas freeing

	Can this operation be carried out at sea?	  	Yes

  

			
	 Heaters

	Cargo Vapor Heater (warm-up)	  	25,000 m^3/h x 2 units (-120°C to 0°C)
	Cargo Vapor Heater (boil-off)	  	5,800 m^3/h x 2 units (-70°C to 45°C)


  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 6	 	










			
	 Guaranteed boil-off rates

	Laden condition	  	0.15% / 24h
	Ballast condition	  	0.10% / 24h

  

			
	 Fuel Gas Vaporizers

	LNG vaporizer	  	23,100 kg/h x 1 unit
	Forcing vaporizer	  	5,200 kg/h x 1 unit

  

	1.6	MEASURING APPARATUS 

  

					
	 	  	 Type and location
	  	 Number

			
	 Primary level gauge system
  

Secondary level gauge system
	  	 Radar sensor, top of each tank
  

Radar sensor
	  	 4
  

4

			
	Cargo temperature	  	 Temperature sensor;
  

Vapor space at liquid dome +
  

Liquid space (0,50,95%) on tank bottom and pump column
	  	 40
  

2 x 5 in each tank

			
	Absolute pressure transmitter	  	Vapor dome of each tank	  	4

  

	1.7	CARGO LINES 

 [Note: Manifold layout sketch to be inserted, when complete] 

 

			
	Is vessel fitted with midship manifolds	  	Yes, 2
	 Distance from cargo manifold to stem (FP)
	  	132 m
	 Distance from manifold to stern (AP)
	  	138 m
	 Height cargo manifold above deck
	  	4.8 m
	 Height manifold above working platform
	  	1.4 m
	 Height cargo manifold above waterline when light
	  	21.2 m
	 Height cargo manifold above waterline when loaded
	  	19.4 m
	 Distance manifold from ship’s rail
	  	3.15 m
	 Distance between loading and vapor return connections
	  	30 m
	 Is vessel fitted with stern discharge
	  	No
	 Is vessel fitted with fore discharge
	  	No


  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 7	 	










					
	 Dimension of lines

	 	  	 Diameter
	  	 Flange size

	 Liquid
	  	600 mm	  	16”
	 Vapour Line
	  	600 mm	  	16”

  

					
	 What reducers onboard

	 Number
	  	 Diameter
	  	 Pressure rating

	8	  	16”/12”	  	10 kg/cm^2

  

	1.8	LNG REGASIFICATION SYSTEM 

  

			
	 Liquid inlet conditions:
	  	
		
	 Pressure
  

Temperature
  

Liquid volume flow
  

Composition (mass %)
	  	 5 bara
  

-160°C (256°F)
  

479.8 m^3/h x 3 units
  

Typical Trinidad composition as given in Appendix 1 to Schedule 1, para 11(c)

		
	 Gas outlet condition:
	  	
		
	 Volume
	  	250 mmscuf/day x 3 units
		
	 Pressure
	  	105 bar
		
	 Temperature
	  	10°C
		
	 Capacity
	  	210,000 kg/hr x 3 units
		
	 LNG booster pump number
	  	6 units
		
	 LNG booster pump discharge pressure
	  	120 bar
		
	 LNG booster pump suction pressure
	  	5 bar
		
	 LNG booster pump temperature
	  	-160°C
		
	 Steam pressure from boilers (saturated)
	  	28 kg/cm^2
		
	 LNG/brine Shell & Tube heat exchanger
	  	3 units
		
	 Steam/brine PCHE
	  	3 units
		
	 Brine circulation pump
	  	680 m^3/h x 6 units


  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 8	 	










	1.9	GAS METERING SYSTEM 

  

			
	 Ultrasonic Gas Metering System
	  	 Ultrasonic gas flow meters x 2 units

 
 Pressure transmitters x 2 units

 
 Temperature transmitters x 2 units

		
	 Gas Analyzer System
	  	 Sample probe x 1 unit
  

Gas chromatographs x 2 units
  

Pressure reduction cabinet x 1 unit
  

Analyzer cabinet x 1 unit

		
	 Metering Control System
	  	 Metering cabinet x 1 unit
  

Flow computers x 2 units


  

	1.10	BALLAST SYSTEM 

  

			
	 Pumps
	  	Particular
	 No.
	  	Three (3)
	 Type
	  	Vertical single stage, centrifugal
	 Prime mover
	  	Electric motor
	 Discharge rate
	  	2,500 m3/h
	 Total head
	  	30 mwc (S.G.: 1.025)

  

	1.11	ODORANT INJECTION SYSTEM 

 [TBN] 

  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 9	 	










	1.12	LIFTING DEVICE 

  

							
	 Location
	  	 Aft
	  	 Amidships
	  	 fwd

				
		  	STB and Port	  	 Manifold area
  

Stb and Port
	  	Regas and STL area
				
	Number and lifting capacity	  	 1 x 15 mt SWL

(STB)
  

1 x 5 mt SWL

(Port)
	  	2 x 12 mt SWL	  	1 x 25 mt SWL
				
	Max distance from ship’s side of lifting hook	  	5 m	  	5 m	  	5 m


  

					
	Execution version – Hull No. 1688	 	Schedule I – Page 10	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 APPENDIX I TO 

SCHEDULE I 
 TO 

DATE 
 VESSEL
PERFORMANCE STANDARDS 
 Diesel Electric 
  

	1.	At Delivery the Vessel shall be compatible with the following LNG import and export terminals capable of accepting LNG carriers having a capacity greater than one hundred twenty thousand cubic meters (120,000m3) 

  

	 	(a)	Loading Terminals: 

  

	 	(i)	Terminals under class 1 

 ***** 

 

	 	(ii)	Terminals under class 2 

 ***** 

 

	 	(b)	Unloading Terminals: 

  

	 	(i)	Terminals under class 1 

 ***** 

 

	 	(ii)	Terminals under class 2 

 ***** 

The terminal data for the terminals under class 2 shall be acquired with Charterer’s assistance. Unless the data are available before the date of the
Charter, any modification to meet ship-shore compatibilities with those terminals shall be at Charterer’s expense in accordance with Clause 5(a) of the Charter. 

Note: If the terminals listed above have any restrictions on draught, deadweight, displacement, loading arm working range, etc., Owner shall provide Charterer
with ship condition information which may affect volume of cargo or bunker to be loaded. 
  

	2.	During normal operational cycles the Vessel will require the following approximate times as listed for the following process changes when applicable: 


 

					
	Post docking:	  		  	
			
	 - Insulation space nitrogen inert
	  	:	  	20 hrs
			
	 - Drying of cargo tanks
	  	:	  	20 hrs
			
	 - Inerting of cargo tanks
	  	:	  	20 hrs
			
	 - Cargo vapor purging
	  	:	  	20 hrs
			
	 - Cooling down
	  	:	  	10 hrs


  
 Execution version – Hull No. 1688

 Diesel Electric – Appendix I to Schedule I – Page 11 









					
	Pre-docking:	  		  	
			
	 - Warming up
	  	:	  	36 hrs (excluding evaporation of unpumpable liquid)
			
	 - Inerting
	  	:	  	20 hrs
			
	 - Aeration
	  	:	  	20 hrs

  

	3.	The Vessel shall be able to load a full cargo in about twelve (12) hours, excluding the time for connecting, disconnecting, cooling down of piping, loading arms or the Vessel’s cargo tanks, topping up and
custody transfer measurement and provided that the loading terminal is capable of pumping at least 12,000 cubic meters of LNG per hour under a back pressure not exceeding 2.3 berg at the manifold presentation flange employing three (3) liquid
manifolds and including the use of 20/60 mesh strainers, with pre-cooled cargo tanks and vapor connection to shore. The terminal must-also be capable of receiving all return vapor from the Vessel that may be generated through both heat leak and
displacement when loading the Vessel at the above specified flow rate of LNG. This loading time is based on an ATR (Arriving Temperature Requirement) of -130 deg. C. ATR. equals (top temperature + bottom temperature) / 2. 


 

	4.	When operating and discharging LNG as a conventional LNG carrier, the Vessel shall be able to discharge a full cargo using all pumps against no backpressure in not more than twelve (12) hours; provided that the
receiving terminal is capable of receiving at least 12,000 cubic meters of LNG per hour. In that respect, the full cargoes of LNG shall be discharged through three (3) 16-inch liquid arms in about 12 hours (excluding slow starting/pump down)
under maximum back pressure of 4.0 berg of LNG at the manifold discharge flange (after ship strainers: 20/60 mesh) at the half cargo level in the tank with cargo specific gravity of 0.47 and conical strainer on line (simultaneous operation of eight
(8) main cargo pumps and without stripping), with vapor connection to shore. 

  

	5.	When the Vessel is employed in the transportation of LNG, the boil-off per day shall not exceed 0.15% of the Vessel’s total cargo capacity on laden voyages or 0.10% of the Vessel’s total cargo capacity on
ballast voyages. Calculations and determinations in respect of the guaranteed boil-off rate shall be made in accordance with Clause 27 of the Charter. 

  

	6.	The guaranteed speed and fuel consumption of the Vessel pursuant to Clause 27 of the Charter is 19.5 knots up to and including Force 5 on the Beaufort Scale at a consumption of no more than about 130 metric tons of
diesel oil per day or 135 metric tons of HFO with LCV of 10,200 kcal/kg for propulsion purposes only when boil-off gas is not available. When boil-off is available the guaranteed fuel oil consumption shall be reduced by the amount of such boil-off
measured in terms of its equivalency to diesel oil or HFO. 

  

	7.	 The performance of the Vessel in relation to the warranties contained in Clause 27(a) to (c) of the Charter will be checked after each
round-trip, and the results accumulated and compensation, if any, assessed at the end of each relevant performance period (as 



  
 Execution version – Hull No. 1688

 Diesel Electric – Appendix I to Schedule I – Page 12 









	 	
described in paragraph 8 below, the “Performance Period”). For the avoidance of doubt, the performances of the Vessel during each round-trip should not be averaged over the performance
period. Only the non- or lesser performance of the Vessel during each round-trip shall be accumulated in order to assess compensation, disregarding performance over and above the warranties. 


 

	8.	The fast Performance Period shall commence on the date of Delivery of the Vessel and shall end at the time and date of commencement of her first scheduled dry-docking hereunder. The second and each subsequent
Performance Period shall commence on completion of the first and each subsequent scheduled dry-docking as aforesaid and terminate on the commencement of the neat scheduled dry-docking, save that the final period shall terminate upon Redelivery of
the Vessel by Charterer to Owner. 

  

	9.	Actual Discharge Rate of Regasified LNG 

 If no discharge of regasified LNG is currently ongoing
from the Vessel at the Deepwater Port, measurement of the Actual Discharge Rate shall commence when the vaporizers, piping and pressurizing risers are cooled down and the last high pressure pump required to achieve the ordered discharge rate is
placed on line when the Vessel starts the discharge cycle of a complete cargo after having arrived at, and after being securely connected to, the Buoy System, and if no overlap from another Vessel is envisaged, shall terminate when the first high
pressure pump is secured near the end of the discharge cycle of a complete cargo of LNG and the Vessel is prepared to disconnect from the Buoy System and proceed to the next load port (the “Discharge Period”). 

Prior to the commencement of a Discharge Period a notification of Readiness to Discharge Gas (as defined in the Gas Nominations Procedures) in
accordance with the Gas Nomination Procedures shall be delivered and a Discharge Period shall start no later than six (6) hours after the above notification, unless such time is extended by reasons attributable to the Charterer, the Neptune
Port Director, governmental or regulatory authorities or Force Majeure (as defined in the Gas Nominations Procedures). 
 The Actual
Discharge Rate shall be the rate of regasified LNG discharged as measured by the Vessel’s metering station. 
  

	10.	The performance of the Vessel in relation to the warranty contained in Clause 27(g) shall be checked at the end of each Discharge Period, and the results accumulated and compensation, if any, shall be assessed at the
end of each month. For purposes of establishing whether the Vessel has achieved performance as required under Clause 27(g), the parties shall discount discharges: 


 

	 	(i)	where the Buoy, System and/or the Downstream Systems are not ready or able to receive the Nominated Discharge Rate specified by Charterer in accordance with the Gas Nomination Procedures and at the corresponding
pressures and temperatures; 


  
 Execution version – Hull No. 1688

 Diesel Electric – Appendix I to Schedule I – Page 13 









	 	(ii)	where Charterer has requested any intra-daily upward changes to the Nominated Discharge Rate in accordance with the Gas Nomination Procedure; 


 

	 	(iii)	where Charterer has instructed the Vessel to proceed from the Deepwater Port to another Primary Terminal to discharge the Vessel’s cargo as LNG; 


 

	 	(iv)	where the Vessel is prevented from approaching the Deepwater Port and/or connecting to the Buoy System by any relevant regulatory or governmental authority by reason other than a failure or default on part of the Vessel
or Owner; 

  

	 	(v)	where the Vessel has to disconnect from the Buoy System and/or to depart from the Deepwater Port or is prevented from discharging her cargo as regasified LNG by reason of compliance with the applicable requirements and
guidelines of the Classification Society, the Vessel’s Flag State or any other relevant regulatory authority and/or with such requirements as set out in the SRV Operating Manual in relation to the Vessel’s safe operation, cargo management
and/or filling level restrictions; and 

  

	 	(vi)	occurring during Regas Tests. 

  

	11.	Discharge of LNG and Regasified LNG 

  

	a.	Acceptance Standard 

 The Vessel shall be capable of regasifying LNG in a closed-loop heating mode using steam
from the Vessel’s auxiliary boilers as the primary heating medium at a discharge rate equal to the Acceptance Standard with a pressure of 100 bar and a temperature of 40°F (4.4°C) at that part of the high pressure gas connector
mounted on the swivel (“Discharge Point”) connected to the other part of the high pressure gas connector mounted on the Buoy System. 
  

	b.	Adjustment of Normal Performance 

 Normal Performance shall be adjusted according to the results of the Regas
Tests as conducted in accordance with the Building Contract, the Specifications and this Charter. If the maximum Test Rate obtained during Regas Tests is less than 600 MMScf/day, and Owner has paid Charterer the liquidated damages as provided in
Clause 7(n), the Test Rate shall become the highest level of Normal Performance set out in the table under paragraph 11(c) below, that is the level of Normal Performance for the months of January, February, November and December; provided that if
Charterer elects to exercise its right under Clause 7(o)(ii), then the levels of Normal Performance shall be adjusted as the parties may agree. Other than as stipulated by this paragraph, Normal Performance shall not be adjusted (unless adjusted in
accordance with paragraph 11(c) below). 

  
 Execution version – Hull No. 1688

 Diesel Electric – Appendix I to Schedule I – Page 14 









	c.	Normal Performance 

 Normal Performance (as defined in Clause 27(g)) shall be determined on the basis of a
discharge rate varying on a monthly basis according the table below: 
  

			
	 Month
	  	 Normal Performance in MMScf/day

	January	  	600
	February	  	600
	March	  	450
	April	  	450
	May	  	450
	June	  	450
	July	  	450
	August	  	450
	September	  	450
	October	  	450
	November	  	600
	December	  	600

 When measuring the Actual Discharge Rate against Normal Performance a variation of one percent (1%) shall be allowed.

 For the purposes of establishing the relevant Normal Performance applicable during any Gas Day, the applicable rate of Normal Performance shall be the
rate of Normal Performance applicable to the month during which the Gas Day commences, notwithstanding that the Gas Day may end during the subsequent month. 

Normal Performance shall be based upon LNG with a chemical composition (Mass%) (Typical Trinidad composition) as follows: 

 

					
	 Methane
	  	 	96.17	% 
		
	 Ethane
	  	 	2.74	% 
		
	 Propane
	  	 	0.76	% 
		
	 i-Buthane
	  	 	0.17	% 
		
	 n-Buthane
	  	 	0.15	% 
		
	 Nitrogen
	  	 	0.01	% 

 The actual gas flow rate at the Discharge Point shall be measured using the installed metering unit. Calculations and
determinations of the Vessel’s actual regasified LNG discharge performance shall be in accordance with paragraphs 9 and 10 of this Appendix I. In the event of any adjustment determined pursuant to paragraph 11(b) of this Appendix 1, Charterer
and Owner shall adjust the above-mentioned Normal Performance in a written memorandum. 

  
 Execution version – Hull No. 1688

 Diesel Electric – Appendix I to Schedule I – Page 15 









	12.	Buoy System Connection and Disconnection 

 The Vessel shall be fitted and capable of connecting, disconnecting
and performing regasified LNG discharge operations through the Buoy System in accordance with the SRV Operating Manual. 
 Upon reaching a distance of three
(3) nautical miles from the Buoy System, the Vessel shall be capable of safely approaching, retrieving and completing all connection operations to the Buoy System (including but not limited to cooling down vaporizers and piping and pressurizing
risers) and be capable of being ready to commence regasified LNG discharge operations in a time of no more than six (6) hours, when operating in normal conditions as provided in the SRV Operating Manual, with no adverse influence from swell.
Interference from any other marine activities shall not be an exception to this standard. 
 Upon completion of regasified LNG discharge and the complete
securing of all cargo-related operations (including limited depressurizing of the Buoy System and risers as required based on the operational requirements relating to the Buoy System), the Vessel shall be capable of disconnecting from the Buoy
System, restoring the Buoy System for retrieval by a subsequent vessel, and proceeding en route, in a time of no more than two (2) hours when operating in normal conditions as provided in the SRV Operating Manual with no adverse influence from
swell. Interference from any other marine activities shall not be an exception to this standard. 

  
 Execution version – Hull No. 1688

 Diesel Electric – Appendix I to Schedule I – Page 16 








 SCHEDULE II 

TO 
 LNG CARRIER TIME
CHARTER PARTY 
 DATED MARCH 2007 

BUILDING CONTRACT AND SPECIFICATIONS 

The following documents have been executed and are attached hereto for reference: 
  

	•	 	Shipbuilding Contract for the Construction and Sale of one (1) LNG carrier (Hull no. 1688) fitted out as an SRV by and between Owner, as buyer, and Samsung Heavy Industries Co., Ltd., as Builder, dated 7 April
2006 

  

	•	 	Specifications (Hull no. 1688) dated 5 April 2006 (ref No. GS05171.FS02). 


  

					
	Execution version – Hull No. 1688	 	Schedule II – Page 1	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 SCHEDULE III 

TO 
 SRV LNG CARRIER TIME
CHARTER PARTY 
 DATED MARCH 2007 

HIRE RATE AND ADJUSTMENTS 
  

	1.	The Hire Rate 

 The Hire Rate shall consist of the following three (3) elements: 

 

	1.1	Fixed (Capital) Element (“Fixed Element”) 

  

	(a)	Comprising ***** United States Dollars (US$*****) per day, the Fixed Element shall provide for ownership costs and all remuneration due to Owner under the Charter. The Fixed Element is fixed and not subject to
adjustment (except as expressly provided for in this paragraph 1.1). In respect of each extension period exercised by Charterer pursuant to Clause 6(m) of the Charter, the Fixed Element shall be equal to an amount in United States Dollars which is
***** percent (*****%) of the Fixed Element payable for the Initial Charter Period. 

  

	(b)	The Fixed Element is calculated on the basis of the following assumption 

 ********** 

 

					
	 	  	 22 Aug 2006
	  	 Closing Date

	 15 yr swap rate”
	  	*****	  	
	 “3 yr swap rate”
	  	*****	  	
	 Forward Reference Swap Rate
	  	*****	  	

 If the Forward Reference Swap Rate at eleven o’clock (11:00 hrs) Oslo time on such date after this Charter
becomes effective and unconditional as Owner shall specify (but in any event not later than ***** days after the Charter becomes effective and unconditional), the “Closing Date”, changes from *****%, the Fixed Element shall be adjusted in
the following manner: 
 US$***** per day for each ***** (*****) basis point difference from *****% (up or down). 

 

	(c)	If Charterer has exercised its option to defer delivery of the Vessel under Clause 6 and has not paid the costs (or realized the gains, if any) associated with that deferral as a lump sum in accordance with Clause 6(d),
then the Fixed Element shall be adjusted to reflect such costs or gains. 


  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 1	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	(d)	Attachment 3 to this Schedule III contains a list of spare parts to be agreed by Owner and Charterer on the basis that it shall increase, pro rata, the Fixed Element by ***** United States Dollars (US$*****) per day,
pro rata, for each ***** United States Dollars (USS*****) of spare parts selected from this Attachment 3. 

  

	(e)	The Fixed Element shall be adjusted to reflect all costs incurred, or (as the case may be) all savings realized, by Owner as a result of any change orders requested by Charterer under Clause 10(n) on the basis that:


  

	 	(i)	any costs incurred shall increase, pro rata, the Fixed Element by ***** United States Dollars (US$*****) per day, pro rata, for each ***** United States Dollars (US$*****) of costs incurred by Owner as a result of such
change orders; and 

  

	 	(ii)	any savings realized shall decrease, pro rata, the Fixed Element by ***** United States Dollars (US$*****) per day, pro rata, for each ***** United States Dollars (US$*****) of savings realized by Owner as a result of
such change orders. 

  

	1.2	Variable (Operating Cost) Element (“Variable Element”) 

  

	(a)	Comprising ***** United States Dollars (US$*****) per day, the Variable Element is subject to annual adjustment, up or down, to reflect changes in such operating costs in accordance with paragraph 2 of this Schedule
III. The operating costs, subject to annual approval by Charterer, shall be included in the Hire Rate on a cost-pass-through basis including general maintenance work (but excluding regular drydocking). Regular drydocking, while also paid by
Charterer on a pass-through basis, shall not be included in the Hire Rate but shall be reimbursed separately in accordance with paragraph 1.2(d). 

  

	(b)	 The daily amount representing the Variable Element of the Hire Rate, exclusive of operating costs for Scheduled Dry-docking, shall be, per year
beginning with the Delivery Date, the “Base OPEX Amount”, which shall as of the Delivery Date consist of the components set forth in this paragraph 1.2 of this Schedule III. The below estimates shall be adjusted if necessary as agreed upon
as of the Delivery Date. Owner and Charterer shall meet at a mutually agreed date at least ***** days prior to the Delivery Date for the purpose of establishing revised estimated operating costs for 2009. Thereafter, not later than August 30 of
each subsequent calendar year during the Term, Owner and Charterer shall meet for the purposes of establishing such estimated costs with respect to that year. If, at any time during the year, Owner anticipates that actual expenditures for all
categories specified in paragraph 1.2(c)(i) through (viii) of this Schedule III are likely to exceed the approved estimates in such year by more than ***** percent (*****%), Owner shall prepare and submit a revised estimate to Charterer for
approval (which approval shall not be unreasonably withheld). If such revised estimate is approved by Charterer, Owner shall have the right to have the Hire Rate adjusted accordingly. Such adjustment shall become effective as of the Hire Payment
Date which first occurs following the ***** day after the date upon which Charterer received such revised estimates. Owner shall notify Charterer if Owner foresees that actual total expenditures are likely to exceed the annual budgeted expenditures
by ***** percent (*****%) or U.S. $*****. The excess percentage of ***** percent (*****%) shall be 



  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 2	 	










	 	
exclusive of the currency exchange rate effect for Crew Costs. Drydocking shall not form part of the subsequent 12-month budget. Drydocking expenses shall be paid separately outside of the
Variable Element as provided for in paragraph (d) below. 

  

	(c)	The initial Variable Element for 2009 is based on a 12-month budget for such year of the following items at daily cost: 

  

	 	(i)	Management - which shall cover general back office and support functions, LNG fleet manager, information technology services, maintenance and purchase systems, Quality Assurance, US Security,
accounting, Maritime Personnel department and other similar expenses. 

  

	 	(ii)	Manning & Crew Complement - 

 The Vessel shall have, and
the manning component of the Variable Element in paragraph 1.2 shall be based upon, a complement of fifteen (15) European and/or American officers and fourteen (14) European, American and/or Filipino crew. The complement shall consist of
European and/or American officers and European, American and/or Filipino subordinates. The crew complement is set out as follows: 

Master: European and/or American 

Deck Officers: European and/or American 

Chief Engineer: European and/or American 

Cargo System Engineer: European and/or American 

Engineers: European and/or American 

Electrician: European and/or American 

Ratings: European, American and/or Filipino 

Catering Complement: European, American and/or Filipino 

Total Crew: twenty-nine (29) (excluding cadets) Cadets: two (2) of any given above nationality; provided, however, that Owner
may increase the crew complement at Owner’s discretion and expense (unless such alteration is required by any applicable law, regulation, international convention or direction of any governmental authority having jurisdiction over the Vessel,
in which case any increased costs shall be for Charterer’s account) and may reduce the crew complement with Charterer’s consent (not to be unreasonably withheld). 

Charterer may request carrying American officers as a part of the Vessel’s complement (such additional cost, if any, to be for
Charterer’s account). 
 The costs associated with any Guarantee Engineer (as defined in the Building Contract) or any other of
Builder’s personnel being stationed on the Vessel following delivery of the Vessel, whether for conducting Regas Tests or otherwise, shall not be included in the Variable Element of hire. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 3	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	(iii)	Insurance - which shall cover all net insurance premiums paid with respect to the Vessel for Reimbursable Insurances and any other insurance requested by Charterer pursuant to Schedule IV.


  

	 	(iv)	Consumables - which shall cover provisions (all edible goods, including the cost of transporting, insuring and loading/unloading thereof) and all reasonable amounts, prudently incurred, paid for all
consumables and expendable items of which there is a continuous and fairly regular consumption (e.g., paint, wire, rope, textiles, cleaning material, lubricating oil, additives and electrical and workshop material) and which are reasonably required
for the use of the Vessel, and the cost of transporting, insuring and loading such items, and other similar expenses. 

  

	 	(v)	Miscellaneous - for 2009 not to exceed ***** US Dollars ($*****) which shall cover all reasonable amounts prudently incurred for communications on board the Vessel (ship radio fee, etc.), fees paid to the
Classification Society, regulatory authorities and consultants, managerial travel expenses and other similar costs. 

  

	 	(vi)	Services - which shall cover all reasonable amounts, prudently incurred, paid for assistance to the Vessel by personnel other than the crew such as voyage repairmen and specialists, equipment rentals,
service contracts, fees paid to the Classification Society, regulatory authorities and consultants and other similar expenses. 

  

	 	(vii)	Spares - which shall cover all reasonable amounts, prudently incurred, paid for spare parts (including transportation and insurance), normal replacement of machinery and equipment which has become worn
out, lost, damaged or obsolete, repair and reconditioning of machinery and equipment, and other similar expenses. 

  

	 	(viii)	Damage Deductibles - which shall cover that portion of any insurable loss not recoverable under Owner’s insurance policies because of the provisions for franchises in the insurance policies.


 SUMMARY OF VARIABLE ELEMENT COMPONENTS 

 

																	
	 Category
	  	 Management
	  	 Services
	  	 Spares
	  	 Consumables
	  	 Damage

Deductibles
	  	 Insurance
	  	 Manning
	  	 Misc.

	Base OPEX Amount US$ /Day in the Year of Delivery	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****	  	*****

  

	(d)	 Drydocking expenses shall cover all reasonable amounts, prudently incurred and paid to shipyards for drydocking, replacement of existing equipment,
repairs, maintenance, survey work, machinery repairs and overhaul costs, port charges, tugs, agency fees at shipyard port, all normally required to maintain the Vessel in a thoroughly efficient state




  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 4	 	










	 	
in hull, machinery and gear to maintain classification, all bunker fuel during deviation for repairs and cost of nitrogen in connection with drydocking and to inert void space after repairs and
other similar expenses, less any amounts received or recoverable by Owner from other sources such as insurance proceeds, proceeds from the self risk pool maintained by the Vessel’s manager (if and when applicable), proceeds from claims for
damages against third parties, proceeds from credits or incentives paid to Owner by Builder related to all aspects of the Vessel’s shipyard visit, and applicable guarantees. All drydocking expenses, including drydocking expenses pertaining to
the year 20th drydocking, shall be invoiced to Charterer upon such expenses being incurred by Owner. Such expenses may include interest (at LIBOR) from the time the drydocking expenses are actually incurred by Owner to the time such expenses are
reimbursed by Charterer. 

  

	1.3	Optional (Capitalized Equipment Cost) Element (“Optional Element”) 

 Comprising
(i) any costs payable by Charterer (to the extent not already paid by Charterer, at Charterer’s option, as a lump sum payment in accordance with Clause 42(a)) in respect of changes described in Clause 42(a) of the Charter and (ii) any
new equipment and machinery which Charterer and Owner have agreed should be capitalized. Such costs shall be distributed over the remaining Term (excluding any Extension Period unless such has been declared in accordance with Clause 6 of the
Charter) in accordance with paragraph 2.5 of this Schedule III or in Charterer’s option, in cash against presentation of invoices. 
  

	2.	Annual Adjustment of Hire Rate 

  

	2.1	General 

 At the end of each Hire Period during the Term, there shall be adjustments to the Hire
Rate to reflect the following year’s approved budget. Each such adjustment shall take effect from the first day of the next succeeding Hire Period. 
  

	2.2	Calculation of Hire Rate 

 No later than 30 August of each calendar year commencing 2009
Owner and Charterer shall meet for the purpose of agreeing on the budget for operating costs for the following calendar year. The Variable Element shall be calculated by dividing the agreed estimated operating costs for the calendar year by the
number of days in said calendar year (or pro rata for the first and last Hire Periods). 
  

	2.3	Hire Periods 

 The Charter Term shall be divided into “Hire Periods” defined as follows:
The first Hire Period shall be the remaining part of such calendar year in which the Vessel is delivered to Charterer. Thereafter each calendar year shall constitute a Hire Period up to the last Hire Period, which shall be calculated from
January 1 in the year during which Redelivery from Charterer to Owner takes place up to and including the date of Redelivery. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 5	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	2.4	Audit 

 In addition to the audit rights of Charterer set forth in Clause 14(f) (the results of
which may give rise to financial adjustments hereunder), audits shall be conducted as follows: 
 (a) Accounting and Accounting Methods. Immediately
following the end of each calendar year and at such time as the Vessel is redelivered to Owner, an audit shall be conducted of Owner’s and Manager’s books of account or any other books of original entry for financial activity related to
the Vessel (which shall be maintained in U.S. Dollars), at Charterer’s sole expense, for the purpose of determining the actual amounts chargeable in accordance with paragraph 2.4(c) to operate the Vessel during such year in respect of the
Variable Element elements set forth in paragraph 1.4. Such actual amounts chargeable are to be determined following International Accounting Standards (“IAS”) as published by the International Accounting Standards Committee, and
considering shipping industry practices. Unless agreed otherwise, Generally Accepted Accounting Principles in Norway will prevail for purposes of the Charter. 

(b) Cooperation. Audits referred to in paragraph 2.4(a) shall be conducted in accordance with the International Standards of Auditing published by the
International Federation of Accountants (“ISA”) then in effect including, but not limited to, reviews of the controls and procedures applicable to those costs subject to audit and confirmation. For purposes of such audit, Owner shall make
available or shall cause to be made available to Charterer and its auditor access to such parts of the offices of Owner and Manager during normal business hours as may be required to review such books and records as are relevant or relate to the
Vessel and its operation except books and records which relate solely to the Financial Cost Component. Owner shall assist and cooperate with Charterer in reviewing such books and records and shall provide Charterer with copies and explanations as
may reasonably be requested for the purposes of any audit under this paragraph 2.4(b). Each party shall cooperate to ensure that each such audit is conducted diligently and expeditiously with the objective that such audits shall be completed within
***** days after January 1 of each audit year or from the date of redelivery of the Vessel to Owner. 
 (c) Adjustment for the Variable Element. Based
on the above audit, Charterer shall calculate the daily Variable Element which would have been applicable for the relevant year if actual costs in the aforesaid categories had been used to calculate the Variable Element as opposed to estimates
thereof (the “Adjusted Variable Element”). The difference between (i) the estimated Variable Element determined in accordance with paragraph 1.3 for that year and (ii) the Adjusted Variable Element calculated for that year,
multiplied by the number of days that the Vessel was on-hire during that year, shall be either paid to Owner or refunded to Charterer, as the case may be, within ***** days of the completion of the applicable audit, together with an amount equal to
interest on the amount refunded or paid for the period from the preceding June 30 to the date upon which the refund or payment is made. Such interest shall be calculated at an annual rate of LIBOR plus *****% for each calendar month during such
period (prorated for partial months). Notwithstanding anything herein to the contrary, in no event shall Charterer be required to pay amounts in excess of ***** percent (*****%) of the estimated Variable Element for all categories specified in
paragraphs 1.2(c)(i) through (vii) for any year unless expenditures relating to such excess amounts were approved in writing by Charterer as provided in paragraph 1.2(b). 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 6	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	2.5	Optional Element Calculation 

 The Optional Element shall be calculated by distributing the
relevant costs incurred (to the extent not already paid by Charterer, at Charterer’s option, as a lump sum payment in accordance with paragraph 1.3 of this Schedule III over the remaining Initial Charter Period, plus any extension period if
such has been declared, on an annuity basis at an interest rate equal to a swap rate plus *****%. For purposes of this paragraph 2.5 only, such swap rate shall be established as the swap rate for United States Dollars, as published on Reuters from
day to day, for a period corresponding to the length of the closest period over which the cost is being distributed, quoted on the date of payment of such cost, or, if more than one (1) payment, on the date of the last payment. 

 

	2.6	Delivery Date Readiness 

 Owner warrants that the Vessel will be fully stored, equipped, manned
and ready in all respects for service as of the Delivery Date and therefore any expenditure required to comply with this warranty or to remedy any shortfall therein shall not be charged as an operating cost for the purposes hereof. 

 

	2.7	Late-In-Term Expenditures 

 During the Term, it is recognized that some portion of the
expenditures for dry-docking, maintenance and repair items may accrue to the benefit of Owner after the expiration of the Term, unless Owner confirms to Charterer that it will scrap the Vessel after the Term. If Owner has not confirmed in writing
that it will scrap the Vessel upon expiration of the Term, the parties shall agree upon a portion of said expenditures which accrue to the benefit of Owner after the expiration of the Term, based on a ***** cycle and said portion shall be refunded
to Charterer within ***** days of Redelivery. A pro-rated portion of dry-docking expenditures incurred within ***** months of Redelivery are specifically presumed to accrue to the benefit of Owner after the expiration of the Term. 

 

	2.8	Spare Parts Allowance 

 Owner shall ensure that an adequate inventory of major capital spare parts
(excluding those necessary for SRV operation) is maintained on board the Vessel (or made available to the Vessel aboard any LNG vessel under control by Owner or its affiliates) and evidence this to the Charterer ***** days before delivery. The
inventory of the spare parts to be maintained on board the Vessel, or otherwise available to the Vessel, which is adequate for performance of Owner’s obligations hereunder shall be the list in Attachment 2 to this Schedule III and any other
spare parts otherwise agreed by Owner and Charterer (“Agreed Allowance List”). Charterer shall be entitled to verify the availability of such spare parts upon the entry of the Vessel into service and Owner will, for Owner’s account,
at the request of Charterer remedy any deficiency. Any spare parts consumed must be replaced so as to maintain the inventory of spare parts in accordance with the Agreed Allowance List throughout the Term of the Charter. Any change in the Agreed
Allowance List (either a reduction due to non-replacement of consumed spare parts or order of additional spare parts not included on the Agreed Allowance List) must have Charterer’s prior approval. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 7	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	2.9	Depot/Regasification Spares 

 Depot spares and Regasification Component spares as agreed and
listed in Attachment 3 to this Schedule III shall be stored for the benefit of the SRVs on or prior to the delivery date of the first SRV in the SRV Fleet. The purchase cost of depot spare parts (including the cost of delivery to the place where
they are to be stored for the use of the Vessel and any duties, if applicable, but excluding any administrative costs or continuing preservation and maintenance costs associated therewith) in excess of ***** United States Dollars (US$*****) for use
in maintaining the Vessel and the Regasification Components shall form part of the Fixed Element of each SRV in the SRV Fleet (as calculated in accordance with Clause 1.1(d) of this Schedule III). Owner shall have the right, subject to
Charterer’s consent (not to be unreasonably withheld), to re-adjust the number of Regasification Component depot spares if, after trials and/or initial service period under this Charter, prudent and safe operating practice show that the number
of spares needs to be increased. Owner and Charterer shall examine ways to improve spare parts management giving consideration to the number of SRVs in the SRV Fleet in operation and the number of different managers of such vessels. To enable
verification of spare parts associated with Regasification Components held on shore solely for the use of the Vessel, such parts shall be stored and recorded separately from any parts which are the same or similar which may be held by Owner or
Manager for any other vessel. Owner shall require Manager to maintain records of the stock of spare parts in such a manner that they can be audited and the stock verified at any time during the Team by Charterer’s auditors. Owner shall install,
on board and on shore, at Owner’s expense, an efficient computerized spare parts management system which will enable Manager to accomplish the foregoing. 
  

	2.10	Monthly Reports 

 As soon as possible, but within ***** days after the end of each
calendar month during the Term, Owner shall provide Charterer (in form and substance from time to time satisfactory to Charterer) with: 
  

	 	(i)	a detailed statement of all operating costs incurred during the said month (together with year-to-date activity, cost comparison to approved budget and comparison to the prior year) in the cost categories specified in
paragraph 1.2, and 

  

	 	(ii)	such other operational data as Charterer may reasonably require. 

  

	2.11	Further Meetings 

 In addition to the annual year-end meeting referred to in
paragraph 2.2, Charterer and Owner shall endeavor to meet as required or requested by either Owner or Charterer to discuss reports and other items relevant to the Hire Rate. 
  

	2.12	Proration 

 Operating costs shall only be charged in respect of the Term. Any
reference to “year” herein shall include the portion of the first year following entry into service and the portion of the last year prior to departure from service and for such years operating costs will be prorated from the Delivery Date
in the case of the first year and the date of redelivery in the case of the last year. The principle set out in this paragraph 2.13 shall apply to the extension periods. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 8	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	3.	Disputes 

 In the event Charterer and Owner are unable to resolve their differences
within ***** days after notice thereof with regard to: 
  

	 	(a)	the scope or contents of any preventative maintenance program or dry-dock specification; 

  

	 	(b)	the extent to which any Optional Element accrues to the benefit of Owner; 

  

	 	(c)	any issue concerning budget estimates and adjustments to the Variable Element; 

  

	 	(d)	the reasonableness of any cost estimate; 

  

	 	(e)	the actual amount incurred in respect of any approved budgeted cost category during any year; or 

  

	 	(f)	any other issue relating to the computation or adjustment of the Hire Rate; 

 then the dispute shall be
referred (at Owner’s and Charterer’s joint expense) for a decision to an independent expert of recognised standing with experience in the operation of LNG carrier and/or SRV vessels, to make a determination of the subject matter in
dispute, using the standard of a prudent owner/operator of LNG carriers/SRVs of similar age. Such expert shall be appointed by mutual agreement. In the event parties do not agree on the nomination of the expert within ***** weeks of the referral,
the President of the Royal Institution of Naval Architects shall nominate the expert. Owner and Charterer shall, within ***** days of agreement and appointment of such expert, submit their case to the expert with supporting documents. The expert
shall then evaluate the merits of each respective position and issue a preliminary written decision in relation to the subject matter referred. Each party shall he allowed ***** right to reply to such preliminary decision before the expert proceeds
to a final written decision, which shall be binding on the parties and shall not be subject to any judicial or arbitral review. Owner and Charterer shall abide by, and promptly implement, such final decision. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 9	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	4.	Reduced Rate of Hire for Deficiency in Normal Performance 

 If it has been determined in accordance with
the provisions of Clause 27(g) of the Charter and paragraphs 9, 10 and 11(c) of Appendix I to Schedule I that the Vessel has performed at Reduced Performance during any Discharge Period, then a Hire Rate equal to a reduced rate determined by
multiplying the Fixed Element of the Hire Rate with the factor set out in the table below (the “Reduced Rate”) shall be payable for each of the Gas Days in respect of which an Actual Discharge Rate lower than Normal Performance has been
determined during the Discharge Period in question: error! 
  

									
	 Month
	  	 Below Normal
 Performance but

higher than 450

MMScf/day
	  	 Between 450 and

350 MMScf/day
	  	 Between 350 and

250 MMScf/day
	  	 Below 250

MMScf/day

	January	  	0.94	  	0.83	  	0.70	  	0.70
	February	  	0.94	  	0.83	  	0.70	  	0.70
	March	  	NA	  	0.88	  	0.83	  	0.70
	April	  	NA	  	0.88	  	0.83	  	0.70
	May	  	NA	  	0.88	  	0.83	  	0.70
	June	  	NA	  	0.88	  	0.83	  	0.70
	July	  	NA	  	0.88	  	0.83	  	0.70
	August	  	NA	  	0.88	  	0.83	  	0.70
	September	  	NA	  	0.88	  	0.83	  	0.70
	October	  	NA	  	0.88	  	0.83	  	0.70
	November	  	0.94	  	0.83	  	0.70	  	0.70
	December	  	0.94	  	0.83	  	0.70	  	0.70

  

	5.	Currency Conversion 

 All accounts subject to adjustment under this Schedule III shall be maintained in
United States Dollars except as otherwise provided in this Charter or this Schedule III. Charges, credits and other computations representing transactions in other currencies shall be made at the free market value of such other currencies in terms
of United States Dollars (or, if Owner has been able to secure a better rate, then at such better rate) to the end that Owner neither gain nor lose on account of such computations as the date incurred. 

 

	6.	Termination Fee 

  

	6.1	Calculation of Termination Fee 

 In the event that Charterer exercises its right
to terminate this Charter in accordance with the provisions of Clause 6(r) of the Charter, the termination fee payable by Charterer to Owner shall be calculated in accordance with the following table: 

 

			
	 Timing of No Fault Termination Date

End of:
	  	Termination Fee to Apply
(Million US Dollars)
	 Year 6
	  	*****
	 Year 7
	  	*****
	 Year 8
	  	*****


  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 10	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


			
	 Year 9
	  	*****
	 Year 10
	  	*****
	 Year 11
	  	*****
	 Year 12
	  	*****
	 Year 13
	  	*****
	 Year 14
	  	*****
	 Year 15
	  	*****
	 Year 16
	  	*****
	 Year 17
	  	*****
	 Year 18
	  	*****
	 Year 19
	  	*****
	 Year 20
	  	*****

  

	6.2	Daily Proration 

 Any reference to “year” in the above table shall
include the portion of any year where the No Fault Termination Date does not coincide with the last day of that year (as defined in paragraph 6.3 below). In calculating the termination fee payable by Charterer to Owner for any such year, the
applicable termination fee will be pro-rated on a daily basis from the No Fault Termination Date. 
  

	6.3	Definition of “year” 

 For the purposes of this table, the first year
after Delivery of the Vessel shall commence at 10:00:01 AM GMT on the Delivery Date and shall end at 10:00:00 AM GMT on the three hundred sixty-fifth (365th) day thereafter. Each subsequent year shall commence at 10:00:01 AM following the end
of the immediately preceding year. In the event that the No Fault Termination Date does not fall on an anniversary date, then the termination fee shall be a linear proration to the No Fault Termination Date between the termination fee of the year
before and the year after. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 11	 	









 Attachment 2 to Schedule 111 

Agreed Allowance List of Spare parts 
  

	•	 	One set of intermediate shaft bearing liner 

  

	•	 	One set of reduction gear thrust bearing pads 

  

	•	 	One complete set of propeller shaft reamer bolts for one coupling 

  

	•	 	One complete set of bearings for reduction gearing, including manufacturer’s tools 

  

	•	 	One complete rotating element for each size of centrifugal pump for fire fighting and essential services for propulsion system including ballast pump, each element comprising shaft, shaft sleeve, “impeller”,
wear rings, bearings, shaft seal assemblies 

  

	•	 	For diesel generator engine: 

  

	 	•	 	two complete units comprising of piston with rings, connecting rod with bearings, liner and cylinder head (complete) 

  

	 	•	 	one set of bearings for 12V50DF 

  

	 	•	 	one set of fuel injectors for 12V50DF 

  

	 	•	 	one set of inlet and exhaust valves for one cylinder 

  

	 	•	 	one set of gaskets for 12V50DF 

  

	 	•	 	one set of fuel pipes for 12V50DF 

  

	 	•	 	each one set of fuel pump for 12V50DF & 6L50DF 

  

	•	 	Spares for electronic instrumentation equipment shall be provided with one unit for every 10 units fitted except electronic instrumentation fitted on the packaged equipment that is to be provided as per manufacturer
standard. 

  

	•	 	For electronic system, one complete spare circuit board for each and every circuit board in a system for following system, except spare PCB for PC and it’s accessories. 


 

	 	•	 	Integrated Automation System 

  

	 	•	 	Custody Transfer System 

  

	 	•	 	DF Engine Control System 

  

	 	•	 	Propulsion Motor Control system 

  

	 	•	 	Emergency Shutdown System 

  

	•	 	One set of manufacturer’s recommended spare parts should be supplied for each control valve and actuator. In addition, spare valve trims (seat) should be provided for the valves having pressure drop ranging from 28
barg to 5 barg or below spray water valves. 

  

	•	 	10% of internal component for each type of luminaries except floodlights, searchlights and nav. & signal lights, from a minimum 1 to maximum 5. 


 

	•	 	10% of each type of indicator lamp, fuse and miniature circuit breaker used for consoles, starters, control panels. 

  

	•	 	Spare parts for generator starter shall be provided as per the spare parts requirement for separate starter. 

  

	•	 	One set of bearing shell and seal, and one set of excitation rectifiers for each type of generator 

  

	•	 	One Automatic Voltage Regulator, complete, each type 

  

	•	 	For Switchboards and Starters: 

  

	 	•	 	Circuit break each size and type 


  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 12	 	










	 	•	 	Fuse-switch unit each size and type 

  

	 	•	 	Relay complete each size 

  

	 	•	 	Two “Start/Stop” push elements 

  

	 	•	 	Two “Stop” elements (if different) 

  

	 	•	 	One selector switch of each type (min 2 if interchangeable) 

  

	 	•	 	10% thermistor control relays 

  

	 	•	 	Three overload elements of each size (where fitted) 

  

	 	•	 	One timing device each size 

  

	 	•	 	10% each size H.R.C. fuse elements fitted 

  

	 	•	 	One complete contractor of each size 

  

	 	•	 	One control transformer of each size 

  

	 	•	 	10% operating or other coil of each type (min 2) 

  

	•	 	For Separate Starters (One complete set for all separate starter, if it is same design) 

  

	 	•	 	Relay complete each size 

  

	 	•	 	10% thermistor control relays 

  

	 	•	 	Three overload elements of each size (where fitted) 

  

	 	•	 	One timing device each size 

  

	 	•	 	One set each size H.R.C. fuse elements 

  

	 	•	 	One complete contactor of each size 

  

	 	•	 	One control transformer of each size 

  

	 	•	 	One operating or other coil of each type 

  

	 	•	 	One set springs, moving contacts and other parts subject to burning or wear for each size of contactor 

  

	•	 	One set bearings for each size and type of motor 

  

	•	 	Six sets thermistor elements 

 The Agreed Allowance List of Spare Parts in this Attachment 2 to Schedule III
shall, throughout the Vessel’s construction phase, be evaluated by Charterer and Owner with a view toward optimising the Depot Spare Parts list in Attachment 3 to Schedule III and ensuring the most practicable arrangement with regard to onboard
spare parts and depot spares. Charterer’s final decision in regard to both shall he challengeable by Owner only upon grounds that such decision is unreasonable under the circumstances. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 13	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 Attachment 3 to Schedule III - Depot spare part list 

 

									
	 NO. or

sets

required
	  	 Description
	  	Cost (US$)
FOB	 	  	Estimated lead
time
	 1
	  	Tail shaft with propeller nut	  	 	*****	  	  	*****months
	 1
	  	Propeller	  	 	*****	  	  	*****months
	 1
	  	 Main wheel with output shaft and both pinion gear with shafts
  

(Pinion gear with shaft to be delivered as raw material, which to be finally machined at that time when needed)
	  	 	*****	  	  	*****months
	 1
	  	Dual fuel generator engine crankshaft	  	 	*****	  	  	*****months
	 1
	  	Dual fuel generator engine internal gear drives for camshaft, including bearings, for each type of installed generator engine	  	 	*****	  	  	*****months
	 1
	  	 Dual fuel generator engine turbo charger, complete, for each type of installed generator engine

 
 (interchangeable with 12V50DF & 6L50DF
	  	 	*****	  	  	*****months
	 1
	  	Cargo pump, complete	  	 	*****	  	  	*****months
	 1
	  	LNG booster pump	  	 	*****	  	  	*****months
	 1
	  	Regas feed pump	  	 	*****	  	  	*****months
	 1
	  	Cargo spray pump, complete	  	 	*****	  	  	*****months
	 1
	  	Fuel gas pump, complete	  	 	*****	  	  	*****months
	 1
	  	Electric generator for emergency generator set	  	 	*****	  	  	*****months
	 1
	  	 Electric generator for each type of installed generator engine

1 set x 5,500 kW (USD 400,000)
 1 set c 11,000 kW (USD
630,000)
	  	 	*****	  	  	*****months
	 1
	  	Frequency/speed inverter control including propulsion transformer for main propulsion motor	  	 	*****	  	  	*****months
	 1
	  	Main propulsion motor	  	 	*****	  	  	*****months
	 1
	  	Each type HV transformer excluding propulsion transformer	  	 	*****	  	  	*****months
	 1
	  	 One electric FDF motor for two regas boilers
  

(Interchangeable with both FDFs)
	  	 	*****	  	  	*****months
	 1
	  	 One mechanical FDF including shaft bearings for two regas boilers
  

(Interchangeable with both FDFs)
	  	 	*****	  	  	*****months
	 1
	  	Turning gear motor for reduction gear	  	 	*****	  	  	*****months
	 1
	  	 Complete safety valve for regas boilers

(total 4 valves with same size for 2 regas boilers)
	  	 	*****	  	  	*****months


  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 14	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


									
	 1
	  	 Complete pilot valve for cargo tank safety valves
  

(each size and each type)
	  	 	*****	  	  	*****months
	 1
	  	Complete expansion bellow (compensator) of each size and each type in the cargo pipe lines	  	 	*****	  	  	*****months
	 1
	  	 Complete manifold valve including actuator
  

(each size and each type, butterfly valve)
	  	 	*****	  	  	*****months
	 1
	  	Complete valve with actuator, cargo pump discharge valve on tanks (each size and each type, butterfly valve)	  	 	*****	  	  	*****months
	 1
	  	 Essential Motor
  

As low voltage motors are taking short lead time, we propose to have each one set of following large HV motors as depot spare:

 
 -Motor for HD Compressor

-Motor for LD Compressor
 -Motor for Bow Thruster

-Motor for Stern Thruster
 -Motor for ballast pump
	  	 	*****	  	  	*****months
		  		  	  
	  
	 	  	  

		  	Total	  	 	*****	  	  	

 The Depot Spare Parts list in this Attachment 3 to Schedule III shall, throughout the Vessel’s construction phase, be
evaluated by Charterer and Owner with a view toward optimizing such list and ensuring the most practicable arrangement with regard to onboard spare parts and depot spares. Charterer’s final decision in regard to both shall be challengeable only
upon grounds that such decision is unreasonable under the circumstances. The cost shall be reference only and shall be changed according to the final specification of the equipment and delivery schedule. 

  

					
	Execution version – Hull No. 1688	 	Schedule III – Page 15	 	









 SCHEDULE IV 

TO 
 SRV LNG CARRIER TIME
CHARTER PARTY 
 DATED MARCH 2007 

INSURANCE 
 THE FOLLOWING IS AT ALL
TIMES SUBJECT TO THE PROVISIONS OF Schedule HI REGARDING THE ALLOCATION OF INSURANCE COSTS IN THE VARIABLE ELEMENT: 
 PART A - Types of Insurance
Coverage 
 Owner shall at all times during the Term procure and maintain insurances on the Vessel in accordance with the following provisions. The
Vessel may be insured under the manager’s fleet policies, subject to Charter’s approval, provided always that the manager provides evidence to Charterer at the renewals of such policies that the insurance policies and cover are sufficient.
In all instances, Owner shall work toward establishing, and Charterer shall approve (such approval not to be unreasonably withheld, conditioned or delayed), insurance values, amounts, coverages and deductibles which result in the most economical
premiums as compatible and consistent with insurances to the standards which prudent shipowners operating first class LNG carriers/SRVs should observe in insuring LNG carriers of a similar type, size, age and trade as the Vessel, which take into
consideration operation of the Vessel as an SRV, and which insurances otherwise conform with the terms of the Charter. Before Delivery under the Charter, Owner and Charterer shall agree on insurance cover having regard to the terms of this Schedule
IV. A review of insurance requirements shall be undertaken by Charterer and Owner annually during the term of the Charter to assess the reasonableness of coverage levels, terms and conditions (including any limits on ports at which Vessel may call),
deductibles and premiums. The objective of the review is to ensure that adequate and appropriate insurance protection and security is available at the most reasonable premiums and deductibles possible. Subsequent to each review, without prejudice to
the provisions of paragraph 8 of this Schedule IV, the insurance program outlined in this Schedule IV shall be adjusted based on the mutual agreement of Charterer and Owner. 

 

	1.	“Hull and Machinery Insurance” 

  

	 	(a)	Owner shall take out and maintain “all risk” Hull and Machinery Insurance with first class marine underwriters up to the value set out in this paragraph (the “Insured Value”). 


 

	 	(b)	Unless otherwise agreed, the maximum Insured Value of the Vessel shall be not less than the higher of the market value of the Vessel and the amount required by Owner’s financiers in accordance with market practice.


  

					
	(c)	 	  (i)	  	The Hull and Machinery Insurance shall be placed under the terms of the Norwegian Marine Insurance Plan applicable at the date of original issue and the date of each renewal, respectively, or its U.K., French, or American
equivalents.


  

					
	Execution version – Hull No. 1688	 	Schedule IV – Page 1	 	










	 	(ii)	In the event that the Hull & Machinery Insurance to be placed by Owner is no longer an “all risk coverage”, Charterer shall determine in conjunction with Owner whether the Hull and Machinery Insurance
specifically shall include the following: 

  

	 	A.	Additional Perils Clause (LNG vessel); or 

  

	 	B.	The (London) Institute Additional Perils Clause-Hulls; or 

  

	 	C.	The American Hull Syndicate Liner Negligence Clause; and 

  

	 	D.	Such additional coverages and insured values as Charterer may reasonably require. 

 In
addition, the Hull and Machinery Insurance shall include Four-fourths Running Down Clause cover; provided, however, that all or a portion of such risk may be taken out by means of P&I Insurance, as defined in paragraph 2, with any of the leading
international P&I associations proposed by Owner and approved by Charterer (the “Approved Club”), which approval shall be granted if the P&I association proposed is a member of the International Group of P&I Associations. 

 

	 	(iii)	Owner shall arrange for, and Charterer shall approve (such approval not to be unreasonably withheld or delayed), a deductible on Hull and Machinery Insurance which results in the most economical premiums recognizing
conditions or restrictions within the financial arrangements pertaining to the Vessel and the standards which prudent shipowners operating first class LNG carriers should observe in insuring LNG carriers of similar type, size, age and trade as the
Vessel which take into consideration outfitting and operation of the Vessel as an SRV and which deductible otherwise conforms with the terms of the Charter. Owner shall make such arrangements as are necessary, to conform to the Conditions of Use
referred to in paragraph 2(c), modified as provided therein. 

  

	2.	Protection & Indemnity Insurance (“P&I Insurance”) 

  

	 	(a)	P&I Insurance shall be placed up to the maximum limit available, with and subject to and on the basis of the rules of the Approved Club. 


 

	 	(b)	The terms of the P&I Insurance shall be those of the standard rules of the Approved Club supplemented or adapted as appropriate in order to adequately insure the operation of the Vessel as an SRV. The deductibles
for the P&I Insurance should result in the most economical premiums, recognizing the conditions or restrictions within the financial arrangements pertaining to the Vessel and standards which prudent shipowners operating first class LNG carriers
should observe in insuring LNG carriers of similar type, size, age and trade as Vessel, which take into consideration operation of the Vessel as an SRV and which terms otherwise conform with the terms of the Charter. 


  

					
	Execution version – Hull No. 1688	 	Schedule IV – Page 2	 	










	 	(c)	Special provisions resulting from Owner’s acceptance of the Conditions of Use of terminals (including under the port liability agreement, as referred to in Clause 72 of the Charter) shall be incorporated into the
terms of Owner’s P&I Insurance, or, if not covered by the standard P&I rules or if required by Charterer, additional insurance shall be placed to cover liability under the Conditions of Use (including under such port liability
agreement). 

  

	 	(d)	In the event that Four-fourths Running Down Clause cover is taken out by means of Hull and Machinery Insurance, P&I Insurance coverages shall be reduced but only to the extent necessary to avoid overlap.


  

	 	(e)	If available and requested by Charterer, Owner shall arrange for membership in the International Tanker Owners Pollution Federation to cover the Vessel and/or other voluntary additional pollution cover.


  

	3.	War Risks Insurance 

  

	 	(a)	Owner shall (save as specifically provided in this paragraph) have the same rights and obligations in respect of insurance of war risks as provided for all the risks referred to in paragraphs 1 and 2 hereof and, where
applicable, up to the same amounts of cover. 

  

	 	(b)	Hull and Machinery War Risks Insurance shall cover no less than is covered by the Norwegian Marine Insurance Plan of 1996 or later amendments or its American, or London Institute equivalents and shall correspond with
the applicable clauses in the Hull and Machinery Insurance. 

  

	4.	Compulsory Insurances 

  

	 	(a)	The insurances required under Part A of this Schedule IV (as they may be varied in accordance with paragraphs (b)-(d) below and renewed in accordance with paragraph 8 below) are hereinafter referred to as the
“Compulsory Insurances.” 

  

	 	(b)	Owner may obtain Increased Value Insurance and/or Hull Interest and/or Freight Interest Insurance for an amount agreed to by underwriters and approved by Charterer for a portion of the Insured Value on Hull and
Machinery on terms (so far as applicable) similar to those for the Hull and Machinery Insurance and with the same insurers or others of similar standing. The decision whether to use such insurance and the percentage of the Insured Value to be
covered by such insurance shall be made by Owner, in consultation with Charterer, taking into consideration the amount of premium savings (if any) resulting therefrom and the adequacy of the insurance coverage. 


 

	 	(c)	 When the Vessel is idle or laid up, Owner may, or at the request of Charterer and subject to availability shall, arrange port risk insurance in lieu
of insurances required hereunder under terms which are, in the event such coverage is obtained at Charterer’s request, subject to Charterer’s prior approval, insuring the Vessel against the usual risks covered by such terms. The cost of
arranging such 



  

					
	Execution version – Hull No. 1688	 	Schedule IV – Page 3	 	










	 	
coverage shall be for Charterer’s account if such coverage is arranged at Charterer’s request. Owner shall obtain Hull and Machinery Insurance underwriters’ prior consent to such
port risk insurance at the time of each renewal. 

  

	 	(d)	At Charterer’s expense, Owner shall obtain such other insurances, endorsements and clauses to policies and entries as Charterer may from time to time request so long as such insurances, endorsements and clauses are
not prohibited by other Compulsory Insurances. 

 PART B - Premiums and Claims 

 

	5.	Payment of Premiums  

  

	 	(a)	Owner shall be responsible for the timely payment of any and all premiums and calls of whatsoever nature lawfully demanded by insurers for all insurance’s taken out on Vessel. 


 

	 	(b)	If Owner shall default in the payment of any premiums or calls as aforesaid, Charterer may, but shall not in any circumstances be obliged to, pay any such premiums or calls to the brokers who arranged the insurance for
payment to underwriters or direct to the Approved Club in question and Charterer shall then be entitled to deduct any such payments made from the next due payment of hire. 


 

	6.	Reimbursement of Owner 

 If available and requested by Charterer, Owner shall obtain a
time charterer’s entry with the Approved Club in the name of Charterer. 
 If available and requested by Charterer, Owner shall arrange
for Charterer’s liability insurance on terms agreeable to Charterer. 
 In the event that Charterer should want to insure the Vessel
for a higher amount than the Insured Value, this shall be done by placing total loss insurance in the name of Charterer; provided always that such additional insurance is readily available in the insurance market and that the premiums in respect of
such excess shall be for Charterer’s account. 
 In addition to Compulsory Insurances, Owner shall obtain insurance for spare parts in
Transit and Storage, Second Seaman’s and money in care of Master, the latter three (3) insurances together with Compulsory Insurances and together with the three insurances referred to in paragraph one to three above in this Clause 6 being
hereinafter collectively referred to as “Reimbursable Insurances.” Reimbursable Insurances shall be the insurance for which Owner is reimbursed as provided in Schedule III of the Charter (i.e., part of the Insurance category under the
Variable Element). Changes in net premiums for the Reimbursable Insurances shall be dealt with as provided in Schedule III. The expression “net premiums” as used herein or in this Charter means the actual amount expended by or on behalf of
Owner ascertained by deducting from the gross premiums paid the full amount of any return premium (for whatever reason received), commissions, rebates and/or discounts on premiums received by Owner and includes and applies (mutatis mutandis) to
calls payable to the Approved Club. 

  

					
	Execution version – Hull No. 1688	 	Schedule IV – Page 4	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	7.	Claims 

 Except as otherwise agreed by Charterer, Owner shall diligently pursue all
claims which can be made under the Reimbursable Insurances. Any amount not recoverable by Owner from insurers by reason only of default in premium payment or breach of warranties shall be deemed to have been paid to Owner in calculating the Variable
Element in Schedule III of the Charter. Owners shall diligently pursue all claims which can be made under the Compulsory Insurances. Unless the cost of repair is greater than the higher of *****% of the market value or the Vessel’s H&M
insured value Owner may not agree or compromise a total loss without Charterer’s consent (which consent may not be unreasonably withheld, conditioned or delayed) 

PART C - Placing of Insurance; Miscellaneous 
  

	8.	Renewal Quotations 

 Owner shall, at its earliest convenience but in no event less than
***** days before the expiry of any of the Reimbursable Insurances and other insurance, provide Charterer with renewal quotations in sufficient detail to provide Charterer with all the information it reasonably requires to assess Owner’s
intended renewal proposal. Charterer may as soon as possible upon receipt of the required information and not later than ***** days prior to expiry date suggest changes to Owner’s proposed arrangements. Owner shall take into consideration
Charterer’s suggested changes acting as a prudent and reasonable operator. 
 In the event that a type or extent of insurance coverage
specified herein should no longer be available Owner shall inform Charterer accordingly, in which case Charterer and Owner shall in good faith discuss and agree on alternative coverage that best possibly meets the reasonable requirements of both
Charterer and Owner. 
  

	9.	Evidence of Insurance  

 Owner agrees to furnish to Charterer, within ***** days after
the renewal of any insurances obtained by or on behalf of Owner, in respect of the Reimbursable Insurances and other insurances placed for the benefit of Charterer, certified copies of cover notes or a copy of the policies cover notes or
certificates of entry and the latest rules of the Approved Club. At least once annually during the Term, Owner shall deliver to Charterer detailed written information concerning the Reimbursable Insurances and any other insurances covering Vessel
for the benefit of Charterer. The receipt of such information shall not impose any obligation on Charterer. 
  

	10.	Additional War Zone Expenses 

 Notwithstanding anything contained elsewhere in
this Schedule IV and subject to the provisions of Clause 37 of the Charter, all extra expenses incurred by Owner (in relation to insurances) if Vessel is required to trade in areas where there is war or, as determined by the insurers of Vessel, a
warlike situation (de facto or de jure) shall be reimbursed by Charterer to Owner; provided, however, that, if practicable, Charterer shall be given an opportunity of signifying its approval before such expenses are incurred. Charterer
shall reimburse Owner for such expenses upon presentation of reasonable documentation evidencing such expenses. 

  

					
	Execution version – Hull No. 1688	 	Schedule IV – Page 5	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	11.	Waiver of Subrogation, etc.  

 Except as Charterer may otherwise agree, all insurance
policies related to Vessel (other than the P&I Insurance) and its operations shall (a) make Charterer an additional assured party, (b) waive insurers’ rights of subrogation against Charterer, and, to the extent available at
reasonable commercial terms, (c) otherwise recognize, in a manner acceptable to Charterer, Charterer’s interests in Vessel and its operations under the Charter. Except for War Risks Insurance, Owner shall cause all insurers to agree in
writing to give Charterer as much prior written notice as possible, but in no event less than ***** days’ prior written notice, of the cancellation of any insurances which such insurers arrange. 

 

	12.	Insurance Opinion 

 At least annually during the Term, Owner shall deliver to Charterer
an opinion of an internationally recognized independent (not owned by or affiliated with Owner or manager) marine insurance broker to the effect that the insurances carried by Owner with respect to Vessel and its operations conform with the
requirements of this Schedule IV and that the Reimbursable Insurances conform with insurances which prudent owners and operators engaged in the LNG trade should carry for vessels of the type, size, class and age of the Vessel, which take into
consideration operation of the Vessel as an SRV, and are placed with underwriters who meet the brokers’ minimum financial standards. 
  

	13.	Additional Insurances 

 Nothing herein provided shall prevent Owner from arranging, for
its sole benefit and at its own sole expense, additional insurance cover; provided, however, that: 
  

	 	(i)	to the extent that any claim amount recoverable under additional insurance (for which Charterer was directly or indirectly to have received a benefit) is reduced by reason of the existence of any such other insurance,
Owner shall credit Charterer with the amount of such lost benefit; 

  

	 	(ii)	such additional insurance may be purchased but only to the extent permitted by and within the warranties of the conditions on which Vessel’s Hull and Machinery Insurance is written, unless agreement for amending
such warranties is obtained from underwriters. 


  

					
	Execution version – Hull No. 1688	 	Schedule IV – Page 6	 	









 SCHEDULE V 

TO 
 SRV LNG CARRIER TIME
CHARTER PARTY 
 DATED MARCH 2007 

LETTERS OF INDEMNITY 
  

	A	Standard form letter of indemnity to be given in return for delivering cargo without production of the original Bill of Lading 

  

	B	Standard form letter of indemnity to be given in return for delivering cargo at a port other than that stated in the Bill of Lading 

  


	C	Standard form letter of indemnity to be given in return for delivering cargo at a port other than that stated in the Bill of Lading and without production of the original Bill of Lading 


  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 1	 	









 A LETTER OF INDEMNITY 

(delivering cargo without production of the original Bill of Lading) 
  


			
	To:	  	[                    ] the Owner of the LNG Carrier (insert name of ship)
		
	Ship:	  	[insert name of ship]
		
	Voyage:	  	[insert load/discharge port, as stated in the Bill of Lading]
		
	Cargo:	  	[insert description of cargo and quantity]
		
	Bill(s) of Lading:	  	[insert identification number, date, place of issue]

 Dear Sirs, 
 The above cargo was
shipped on the above vessel by (insert name of shipper) and consigned to (insert name of consignee or to whose order the Bill of Lading is made out, as appropriate) for delivery at the port of (insert name of discharge port stated in the Bill of
Lading), but the Bills of Lading have not yet arrived and we (insert name of party requesting delivery), hereby request you to give delivery of the said cargo to (insert name of party to whom delivery is to be made) without production of the
original Bills of Lading. 
 In consideration of your complying with our above request, we hereby agree as follows: 

 

	1.	To indemnify you, your servants and agents and to hold all of you harmless in respect of any liability, loss, damage or expenses of whatsoever nature which you may sustain by reason of delivering the cargo to the above
consignees in accordance with our request. 

  

	2.	In the event of any proceedings being commenced against you or any of your servants or agents in connection with the delivery of the cargo as aforesaid, to provide you or them from time to time on demand with sufficient
funds to defend the said proceedings. 

  

	3.	If, in connection with the delivery of the cargo as aforesaid, the vessel or any other vessel or property belonging to you should be arrested or detained, or if the arrest or detention thereof should be threatened, to
provide on demand such bail or other security as may be required to prevent such arrest or detention or to secure the release of such vessel or property and to indemnify you in respect of any liability, loss, damage or expenses caused by such arrest
or detention or threatened arrest or detention whether or not the same may be justified. 

  

	4.	As soon as all original Bills of Lading for the above cargo shall have arrived and/or come into our possession to produce and deliver the same to you, whereupon, subject to Clauses 1, 2 and 3 above, our liability
hereunder shall cease. 

  

	5.	The liability of each and every person under this indemnity shall be joint and several and shall not be conditional upon your proceeding first against any person, whether or not such person is party to or liable under
this indemnity. 

  

	6.	This indemnity shall be governed by and construed in accordance with English Law and each and every person liable under this indemnity shall at your request submit to the jurisdiction of the High Court of Justice in
London. 


  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 2	 	










			
	Yours faithfully,
	
	for and on behalf of
	
	Charterer
	
	  

	
	signature
	
	stating name and position of signatory
	
	We join in the above Letter of Indemnity
	
	  



  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 3	 	









 B LETTER OF INDEMNITY 

(delivering cargo at a port other than that stated in the Bill of Lading) 

 

			
	To:	  	[                    ] the Owner of the LNG Carrier (insert name of ship)
		
	Ship:	  	[insert name of ship]
		
	Voyage:	  	[insert load/discharge port, as stated in the Bill of Lading]
		
	Cargo:	  	[insert description of cargo and quantity]
		
	Bill(s) of Lading:	  	[insert identification number, date, place of issue]

 Dear Sirs, 
 The above cargo was
shipped on the above vessel by (insert name of shipper) and consigned to (insert name of consignee or to whose order the Bill of Lading is made out, as appropriate) for delivery at the port of (insert name of discharge port stated in the Bill of
Lading), but we, (insert name of party requesting substituted delivery), hereby request you to order the vessel to proceed to and give delivery of the said cargo at the port of (insert name of substitute port) against production of at least one
original Bill of Lading. 
 In consideration of your complying with our above request, we hereby agree as follows: 

 

	1.	To indemnify you, your servants and agents and to hold all of you harmless in respect of any liability, loss, damage or expenses of whatsoever nature which you may sustain by reason of the vessel proceeding and giving
delivery of the cargo at the substitute port in accordance with our request. 

  

	2.	In the event of any proceedings being commenced against you or any of your servants or agents in connection with the vessel proceeding and giving delivery of the cargo as aforesaid, to provide you or them from time to
time on demand with sufficient funds to defend the said proceedings. 

  

	3.	If, in connection with the vessel proceeding and giving delivery of the cargo as aforesaid, the vessel or any other vessel or property belonging to you should be arrested or detained, or if the arrest or detention
thereof should be threatened, to provide on demand such bail or other security as may be required to prevent such arrest or detention or to secure the release of such vessel or property and to indemnify you in respect of any liability, loss, damage
or expenses caused by such arrest or detention or threatened arrest or detention whether or not the same may be justified. 

  

	4.	The liability of each and every person under this indemnity shall be joint and several and shall not be conditional upon your proceeding first against any person, whether or not such person is party to or liable under
this indemnity. 

  

	5.	This indemnity shall be governed by and construed in accordance with English Law and each and every person liable under this indemnity shall at your request submit to the jurisdiction of the High Court of Justice in
London. 


  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 4	 	










	
	Yours faithfully,
	
	for and on behalf of
	
	Charterer
	
	  

	
	signature
	
	stating name and position of signatory
	
	We join in the above Letter of Indemnity
	
	  



  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 5	 	









 C LETTER OF INDEMNITY 

(delivering cargo at a port other than that stated in the Bill of 

Lading and without production of the original Bill of Lading) 
  

			
	To:	  	[                    ] the Owner of the LNG Carrier (insert name of ship)
		
	Ship:	  	[insert name of ship]
		
	Voyage:	  	[insert load/discharge port, as stated in the Bill of Lading]
		
	Cargo:	  	[insert description of cargo and quantity]
		
	Bill(s) of Lading:	  	[insert identification number, date, place of issue]

 Dear Sirs, 
 The above cargo was
shipped on the above vessel by (insert name of shipper) and consigned to (insert name of consignee or to whose order the Bill of Lading is made out, as appropriate) for delivery at the port of (insert name of discharge port stated in the Bill of
Lading), but we, (insert name of party requesting substituted delivery), hereby request you to order the vessel to proceed to and give delivery of the said cargo at the port of (insert name of substitute port) to (insert name of party to whom
delivery is to be made) without production of the original Bill(s) of Lading. 
 In consideration of your complying with our above request, we hereby agree
as follows: 
  

	1.	To indemnify you, your servants and agents and to hold all of you harmless in respect of any liability, loss, damage or expenses of whatsoever nature which you may sustain by reason of the vessel proceeding and giving
delivery of the cargo without production of the original Bill of Lading and at a port other than that stated in the Bill of Lading, in accordance with our request. 


 

	2.	In the event of any proceedings being commenced against you or any of your servants or agents in connection with the vessel proceeding and giving delivery of the cargo as aforesaid, to provide you or them from time to
time on demand with sufficient funds to defend the said proceedings. 

  

	3.	If, in connection with the vessel proceeding and giving delivery of the cargo as aforesaid, the vessel or any other vessel or property belonging to you should be arrested or detained, or if the arrest or detention
thereof should be threatened, to provide on demand such bail or other security as may be required to prevent such arrest or detention or to secure the release of such vessel or property and to indemnify you in respect of any liability, loss, damage
or expenses caused by such arrest or detention or threatened arrest or detention whether or not the same may be justified. 


  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 6	 	










	4.	As soon as all original Bills of Lading for the above cargo shall have come into our possession to produce and deliver the same to you. 


 

	5.	The liability of each and every person under this indemnity shall be joint and several and shall not be conditional upon your proceeding first against any person, whether or not such person is party to or liable under
this indemnity. 

  

	6.	This indemnity shall be governed by and construed in accordance with English Law and each and every person liable under this indemnity shall at your request submit to the jurisdiction of the High Court of Justice in
London. 

  

	
	Yours faithfully,
	
	for and on behalf of
	
	Charterer
	
	  

	
	signature
	
	stating name and position of signatory
	
	We join in the above Letter of Indemnity
	
	  



  

					
	Execution version – Hull No. 1688	 	Schedule V – Page 7	 	









 SCHEDULE VI 

TO 
 SRV LNG CARRIER TIME
CHARTER PARTY 
 DATED MARCH 2007 

FORM OF REGAS TESTS ACCEPTANCE CERTIFICATE 

REGAS TESTS ACCEPTANCE CERTIFICATE under SRV TIME CHARTERPARTY FOR HULL No. 1688 dated
             2007 (the “Charter”) 
 This document constitutes the Regas Tests
Acceptance Certificate envisaged Clauses 7(f), 7(i), 7(l) and 7(s) of that certain SRV LNG Carrier Time Charterparty in respect of one 145,000 m3 shuttle and regasification vessel having
Builder’s Hull No. 1688, dated [—][—] 2007 (the “Charter”), signifying that: 

 

	 	1)	the Regas Tests (as defined in the Charter) have been completed satisfactorily in accordance with the requirements of the Charter and the Specifications; and 


 

	 	2)	[the Guaranteed Regas Rate (as defined in the Charter)][an actual regas rate of [            ]] has been achieved[; and] 


 

	 	3)	[no amount is due and payable to Charterer by Owner under Clause 7(n) of the Charter][liquidated damages in the amount of US$ [—] (United States Dollars [—]), as calculated in accordance with Clause 7(n) of the Charter are due and payable by Owner in accordance with the provisions of Clause 7(n) of the Charter]. 


Capitalised words used in this Certificate shall have the meaning accorded them in the Charter. 

Charterer’s execution of this Certificate shall in no respect release Owner from its obligations and liability: 

 

	 	a)	[to pay to Charterer the amount in liquidated damages referred to in paragraph 3 above]; [and 

  

	 	b)	under Clause 27(g) of the Charter for the duration of the Term]. 

 Signed on this [    ]
day of [        ] 200[  ]: 

  

					
	Execution version – Hull No. 1688	 	Schedule VI – Page 1	 	










					
	  
	 		 	  

	by [                    ]	 		 	by [                    ]
	for and on behalf of	 		 	for and on behalf of
	SRV JOINT GAS LIMITED	 		 	SUEZ LNG TRADING SA


  

					
	Execution version – Hull No. 1688	 	Schedule VI – Page 2	 	









 SCHEDULE VII 

TO 
 SRV LNG CARRIER TIME
CHARTER PARTY 
 DATED MARCH 2007 

FORM OF CONSENT AND AGREEMENT 

CONSENT AND AGREEMENT (this “Consent”), dated as of             ,
20    , among (1)                     , a company organised and existing under the laws of the
                    (the “Charterer”); (2)
                    , as Security Trustee (together with its successors in such capacity, the “Security Trustee”) for the sole benefit of
the Finance Parties under the Finance Documents (as each such term is defined below); and (3)                     , a company organised and existing
under the laws of                      (the “Borrower”). 

RECITALS 
 A. The Vessel.
The Borrower will be the registered owner of a              cubic meter liquefied natural gas tanker [under construction]/[to be constructed] at
                     and having hull number              (the “Vessel”) which
the Borrower will acquire from                      (the “Ship Builder”) pursuant to a shipbuilding contract dated
                     between the Borrower and the Ship Builder (the “Ship Building Contract”). 

B. The Charter. Pursuant to a time charterparty dated
                     made between the Charterer and the Borrower in respect of the Vessel (the “Charter”), the Charterer will charter the
Vessel from the Borrower for an initial period of about      years (subject to termination rights) from delivery thereunder. 

C. The Finance Documents. Pursuant to a facility agreement dated
             20     (the “Facility Agreement”) among (i) the Borrower; (ii) the Security Trustee; (iii)
                     (as the “Agent”); and (iv) the banks and financial institutions listed in Schedule     
thereto (the “Lenders”, and together with the Security Trustee, the Agent and the Banks, the “Finance Parties”), the Lenders have agreed, inter alia, to make certain loan facilities available to the Borrower upon the terms and
subject to the conditions of the Finance Documents (as such term is defined in the Facility Agreement). As part of the security for the obligations of the Borrower to the Finance Parties under the Finance Documents, the Borrower has agreed to grant
to the Security Trustee certain security including (inter alia): 
  

	 	(i)	an assignment of its rights under the Charter, and 

  

	 	(ii)	a first priority ship mortgage over the Vessel (the “Mortgage”). 

 D. Condition
Precedent. The Finance Documents require the execution, delivery and implementation of this Consent and it is a condition precedent to the making of 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 1	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 
loans under the Facility Agreement that the Charterer shall have executed and delivered this Consent. It is acknowledged by the Borrower and the Charterer that the execution of this Consent
satisfies the requirement of Clause 14(c) of the Charter. 
 NOW, THEREFORE, in consideration of the foregoing recitals and for other good
and valuable consideration, the receipt of which is hereby acknowledged, the Charterer, the Security Trustee and the Borrower hereby agree as follows: 

ARTICLE 1. - CONSENT TO ASSIGNMENT, ETC. 

1.1 Quiet Enjoyment Undertaking. The Security Trustee for itself and in its capacity as agent for the Finance Parties irrevocably
undertakes that subject to due performance by the Charterer of all its material obligations under the Charter (subject to the expiry of any grace periods), the Security Trustee shall, for the duration of the Charter and any extension thereof
permitted by the Charter, allow the Charterer unfettered use of the Vessel in accordance with the terms and conditions of the Charter. Any breach by the Charterer of its obligations under the Charter shall be subject solely to the rights and
remedies afforded the Borrower under the Charter. The Security Trustee will not exercise any rights it may have against the Vessel or in connection with the Charter if any “event of default” (as that term is defined in the Facility
Agreement, an “Event of Default”) has occurred and is continuing, except as provided by Articles 1.3 and 1.7 below. 
 1.2
Consent to Assignment. The Charterer (i) consents in all respects to the pledge and assignment to the Security Trustee pursuant to the Finance Documents of all of the Borrower’s right, title and interest in, to and under the Charter
and the Ship Building Contract (the “Assigned Interests”); (ii) acknowledges the right of the Security Trustee or any designee of the Security Trustee, in the exercise of the Security Trustee’s rights and remedies under the
Finance Documents, to make all demands, give all notices, take all actions and exercise all rights of the Borrower under the Charter and the Ship Building Contract; and (iii) acknowledges that the Borrower may not, without the prior written
consent of the Security Trustee, materially amend, modify, vary, or supplement, or terminate or assign the Charter or the Ship Building Contract. 

1.3 Substitute Owner. The Charterer agrees that (i) if the Security Trustee shall notify Charterer that an Event of Default has
occurred and is continuing and that the Security Trustee or its designee has elected to exercise the rights and remedies set forth in the Finance Documents, then the Security Trustee or its designee which elects to assume the Borrower’s
obligations under the Charter and the Ship Building Contract (the “Substitute Owner”) shall be substituted for the Borrower under the Charter and the Ship Building Contract; and (ii) in such event, the Charterer shall (without
prejudice to Article 1.4 below) recognise the Substitute Owner and shall continue to perform its obligations under the Charter in favour of the Substitute Owner, provided that (x) the Security Trustee shall give the Charterer not less than
***** days’ prior written notice of the intended transfer and details of the proposed Substitute Owner; (y) in the opinion of the Charterer (acting reasonably and without undue delay), the proposed Substitute Owner shall have the legal
capacity and the financial resources and expertise to own and operate the Vessel and, without limitation, to perform the Borrower’s obligations under the Charter; and (z) such proposed Substitute Owner shall have undertaken to the
Charterer in writing to remedy as soon as practicable any outstanding defaults of the Borrower under the Charter. 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 2	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 1.4 Preservation of Charterer’s Rights. Notwithstanding any other provision in
this Consent, any disposal of the Vessel by the Security Trustee to a Substitute Owner in accordance with Article 1.3 shall not prejudice the Charterer’s rights under the Charter accruing before or after the date of such disposal, including,
without limitation, any right that the Charterer may then have to terminate the Charter (but as between the Charterer and the Finance Parties, subject always to Article 1.5). If the Security Trustee exercises its rights under Article 1.3 above to
dispose of the Vessel to a Substitute Owner during the term of the Charter, the Security Trustee shall comply with the conditions set out in Article 1.1 above and shall (subject to any requirements or restrictions imposed by any applicable law in
relation to disposal of the Vessel) dispose of the Vessel expressly subject to the Charter. The Security Trustee shall procure that the Substitute Owner (and any other person providing financing to the Substitute Owner for the purposes of the
acquisition by the Substitute Owner of the Vessel) issues an undertaking to the Charterer on substantially the same terms as the undertaking granted by the Security Trustee in Article 1.1 above. 

1.5 Right to Cure. In the event of a default or breach by the Borrower in the performance of any of its obligations under the Charter,
or upon the occurrence or non-occurrence of any event or condition under the Charter that would immediately or with the passage of any applicable grace period or the giving of notice, or both, enable the Charterer to terminate the Charter (a
“Default”), to the extent such Default is capable of being cured the Charterer shall not terminate the Charter until it first gives written notice of such Default to the Security Trustee or its designee and affords such party a period of
***** days to cure the circumstances giving rise to such suspension or termination rights; provided, however, that (i) such *****-day cure period shall in no circumstance delay the termination date afforded to Charterer under the Charter and
(ii) such right to cure shall apply only after delivery of the vessel under the Charter and not during construction. 
 1.6
Assignment, Transfer, Sub-chartering. The Charterer agrees that in the event that the Charterer sub-charters the Vessel to any person permitted in accordance with the terms of the Charter, the Charterer shall procure that any such person
undertakes that its rights as sub-charterer are subject and subordinate in all respects to the rights of the Finance Parties under this Consent and that such person shall not assert a claim against the Finance Parties or any of them for wrongful
interference with its rights (or any similar or equivalent claim) in respect of any actions taken by the Finance Parties or any of them which are in compliance with this Consent, and to procure that such undertaking by such person is included in the
terms of any sub-charter entered into between the Charterer and such person. 
 1.7 Replacement Agreement. In the event that the
Charter is terminated as a result of any bankruptcy or insolvency proceeding or other similar proceeding affecting the Borrower, the Charterer shall, at the option of the Security Trustee, enter into a new agreement with the Security Trustee or its
transferee or nominee (the “Replacement Owner”) on terms identical, mutatis mutandis, to the terms of the Charter. The Security Trustee (or, as the case may be, the Replacement Owner) shall comply with the provisions of Article 1.3 (x),
(y) and (z) which shall apply for the purposes of this Article 1.7 as if the words “proposed Substitute Owner” have been replaced by the words “proposed Replacement Owner”. 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 3	 	









 1.8 No Liability. The Charterer acknowledges and agrees that neither the Security Trustee
nor its designees shall have any liability or obligation under the Charter as a result of this Consent, nor shall the Security Trustee or its designees be obligated or required to (i) perform any of the Borrower’s obligations under the
Charter, except during any period in which the Security Trustee or its designee is a Substitute Owner under the Charter pursuant to Article 1.3 or a Replacement Owner under the Charter pursuant to Article 1.7, in which case the obligations of such
Substitute Owner or Replacement Owner shall be no more onerous than those of the Borrower under the Charter for such period (unless otherwise expressly agreed by the Borrower and the Security Trustee or the Substitute Owner or the Replacement
Owner); or (ii) take any action to collect or enforce any claim for payment assigned under the Finance Documents. 
 1.9
Borrower’s Undertaking. The Borrower undertakes to the Charterer that it shall not make any claim against the Vessel and/or the Charterer arising from any transfer or novation of the Charter to the Security Trustee or any Substitute
Owner or from the entry into a new agreement by the Charterer with a Replacement Owner. The Security Trustee acknowledges that delivery by the Borrower of a notice in writing to the Charterer stating that the Borrower has no claim, and has no
intention of making such a claim, against the Vessel and/or the Charterer which may arise from such transfer or novation or from the entry into a new agreement shall be a condition precedent to the effectiveness of any transfer, novation or new
agreement. 
 1.10 Delivery of Notices. The Charterer shall deliver to the Security Trustee and its designees, concurrently with the
delivery thereof to the Borrower, a copy of any notice of suspension or termination given by the Charterer to the Borrower under the Charter. 

1.11 Registration of Interest. To the extent permitted by applicable law, the terms of the undertaking contained in Article 1.1
above shall be included in the Mortgage and shall form part of the terms and conditions of the Mortgage. Upon registration of the Mortgage, the Security Trustee agrees to request that the Registrar of Ships for vessels registered on the Ship
Register make a note of such undertaking in the Vessel’s register. 
 ARTICLE 2. - PAYMENTS UNDER THE CHARTER 

The Charterer shall pay all amounts payable by it to the Borrower under the Charter in the manner required by the Charter directly into the
account specified on Exhibit A hereto, or to such other person or account as shall be specified from time to time by the Security Trustee to the Charterer in writing in accordance with Article 4.1. Should the Charterer receive a notice from the
Security Trustee asking the Charterer to make payments to an alternative account in accordance with this Article 2, the Borrower shall pay to the Charterer any net increase in payment costs incurred by the Charterer as a result of making such
payments into such alternative account. 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 4	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 

 ARTICLE 3. - REPRESENTATIONS AND WARRANTIES OF THE CHARTERER 

The Charterer makes the following representations and warranties to the Security Trustee as at the date hereof. 

3.1 Organisation. The Charterer is duly organised and validly existing under the laws of jurisdiction of its incorporation, and has all
requisite corporate power and authority to execute and deliver this Consent and the Charter and perform its obligations thereunder. 
 3.2
Authorisation; No Conflict. The Charterer has duly authorised, executed and delivered this Consent and the Charter. Neither the execution and delivery of this Consent and the Charter by the Charterer nor its consummation of the transactions
contemplated thereby nor its compliance with the terms thereof does or will require any consent or approval not already obtained, or will conflict with the Charterer’s formation documents or any contract or agreement binding on it. 

3.3 Legality, Validity and Enforceability. Each of this Consent and the Charter is in full force and effect and is a legal, valid and
binding obligation of the Charterer, enforceable against the Charterer in accordance with its terms. The Charter has not been amended, supplemented, suspended, novated, extended, restated or otherwise modified except in accordance with its terms.

 3.4 Governmental Consents. There are no governmental consents existing as of the date of this Consent that are required or will
become required to be obtained by the Charterer in connection with the execution, delivery or performance of this Consent and the Charter and the consummation of the transactions contemplated thereunder, other than those governmental consents which
have been obtained or can be obtained without undue expense or delay. 
 3.5 Litigation. There are no pending or, to the
Charterer’s knowledge, threatened actions, suits, proceedings or investigations of any kind (including arbitration proceedings) to which the Charterer is a party or is subject, or by which it or any of its properties are bound, that if
adversely determined to or against the Charterer, could reasonably be expected to materially and adversely affect the ability of the Charterer to execute and deliver the Charter and this Consent or to perform its obligations thereunder or hereunder.

 ARTICLE 4. - MISCELLANEOUS 

4.1 Notices. All notices or other communications required or permitted to be given hereunder shall be in writing and shall be
considered as properly given (a) if delivered in person, (b) if sent by overnight delivery service or (c) if sent by prepaid telex, or by telecopy with correct answer back received. Notices shall be directed (i) if to the
Charterer or the Borrower, in accordance with the Charter and (ii) if to the Security Trustee, to                     . Notice so given shall be
effective upon receipt by the addressee. Any party hereto may change its address for notice hereunder to any other location by giving no less than ***** days notice to the other parties in the manner set forth hereinabove. 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 5	 	









 4.2 Further Assurances. The Charterer shall fully cooperate with the Security Trustee and
perform all additional acts reasonably requested by the Security Trustee to effect the purposes of this Consent. 
 4.3 Amendments.
This Consent may not be amended, changed, waived, discharged, terminated or otherwise modified unless such amendment, change, waiver, discharge, termination or modification is in writing and signed by each of the parties hereto. 

4.4 Entire Agent. This Consent and any agreement, document or instrument attached hereto or referred to herein integrate all the terms
and conditions mentioned herein or incidental hereto and supersede all oral negotiations and prior writings in respect to the subject matter hereof. 

4.5 Governing Law. This Consent shall be governed by the laws of England. 

4.6 Severability. In case any one or more of the provisions contained in this Consent should be invalid, illegal or unenforceable in
any respect, the validity, legality and enforceability of the remaining provisions shall not in any way be affected or impaired thereby, and the parties hereto shall enter into good faith negotiations to replace the invalid, illegal or unenforceable
provision with a view to obtaining the same commercial effect as this Consent would have had if such provision had been legal, valid and enforceable. 

4.7 Dispute Resolution. Any dispute arising under this Consent shall be decided by the High Court of Justice in London, England to
whose jurisdiction the parties hereby agree. Notwithstanding the foregoing, the parties may jointly agree in writing to have any dispute arising from this Consent referred to or determined by any arbitral tribunal appointed pursuant to Clause 53 of
the Charter. It shall be a condition precedent to the right of any party to a stay of any legal proceedings in which maritime property has been or may be, arrested in connection with a dispute under this Consent, that that party furnishes to the
other party security to which that other party would have been entitled in such legal proceedings in the absence of a stay. 
 4.8
Service of Process. (i) The Charterer hereby appoints Suez Global LNG Ltd., 101 Wigmore Street, third floor, London W1U 1QU (United Kingdom) as its agent for service of any proceedings under this Charter in the High Court of
England and Wales; (ii) the Borrower hereby appoints                      as its agent for service of any proceedings under this Charter in the
High Court of England and Wales; and (iii) the Security Trustee hereby appoints                      as its agent for service of any proceedings
under this Charter in the High Court of England and Wales. 
 4.9 Successors and Assigns. The provisions of this Consent shall be
binding upon and inure to the benefit of the parties hereto and their permitted successors and assigns. 
 4.10 Counterparts. This
Consent may be executed in one or more duplicate counterparts and when signed by all of the parties listed below shall constitute a single binding agreement. 

4.11 Termination. Each party’s obligations hereunder are absolute and unconditional, and no party shall have any right to
terminate this Consent or to be released, 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 6	 	









 
relieved or discharged from any obligation or liability hereunder until the earlier of (i) the irrevocable payment in full of all sums owed to the Finance Parties under the Finance Documents
followed by the discharge of the Mortgage; and (ii) any permanent withdrawal of the Vessel from service under, or termination of, the Charter. 

4.12 Contracts (Rights of Third Parties) Act 1999. A person who is not a party to this Consents may not enforce any of its terms under
the Contract (Rights of Third Parties) Act 1999. 
 IN WITNESS WHEREOF, the parties have caused this Consent to be duly executed and
delivered by its officer thereunto duly authorised as of the date first above written. 
  

							
	[                                    
    ] [CHARTERER]
				
		 		 	By:	 	  

		 		 	Name:	 	  

		 		 	Title:	 	  

	
	[                                    
    ] [BORROWER]
				
		 		 		 	
		 		 	By:	 	  

		 		 	Name:	 	  

		 		 	Title:	 	  

	
	[                                    
    ] [SECURITY TRUSTEE]
				
		 		 	By:	 	  

		 		 	Name:	 	  

		 		 	Title:	 	  



  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 7	 	









 Exhibit A – Payment Instructions 

  

					
	Execution version – Hull No. 1688	 	Schedule VII – Page 8	 	









 SCHEDULE VIII 

TO 
 SRV LNG CARRIER
TIME CHARTER PARTY 
 DATED MARCH 2007 

FORM OF DEED OF GUARANTEE - OWNER’S GUARANTORS 
  

	1.	This Guarantee is a performance and payment guarantee in accordance with the terms herein. In order to induce SUEZ TRADING LNG SA, a Société Anonyme (the “Charterer”) to enter into the SRV LNG
Carrier Time Charter Party with SRV JOINT GAS LIMITED, a Cayman Islands company (the “Owner”), dated [—] (referred to herein as the “Charter”), Höegh LNG Ltd.
(“Höegh”), having its principal place of business at [—] and Mitsui O.S.K. Lines, Ltd. (“MOL”), having its principal place of business at [—] (herein together referred to as the “Guarantors” and individually a “Guarantor”) hereby unconditionally and irrevocably, on a joint and several basis (subject always to the
provisions of Clause 2 of this Guarantee), guarantee to the Charterer, its successors and assigns, the due and punctual performance of all of the obligations of the Owner under the Charter when due. 


 

	2.	Notwithstanding the provisions of Clause 1 above as to the joint and several liability of the Guarantors under this Guarantee, the liability of each Guarantor under this Guarantee as to the due and punctual performance
of any and all payment obligations of the Owner under the Charter shall be several, in each case proportionate to its respective beneficial ownership share of the Owner, being 50% for Höegh and 50% for MOL. 


Each payment demand shall be sent to both Guarantors, specifying the full payment due by the Owner under the Charter, and each guarantor shall
be liable to pay 50% of the requested amount. If for any reason this Guarantee is not enforceable against one of the Guarantors, it remains enforceable against the other Guarantor up to 50% of the requested amount. 

 

	3.	Each Guarantor represents that (a) it is duly organized, validly existing and in good standing under the laws of the jurisdiction of its incorporation and has full corporate power to execute, deliver and perform
this Guarantee; (b) the execution, delivery and performance of the Guarantee have been and remain duly authorized by all necessary corporate action and do not contravene any provision of law or the Guarantor’s constitutional documents or
any contractual restriction binding on the Guarantor or its assets; and (c) this Guarantee constitutes the legal, valid and binding obligation of the Guarantor enforceable against the Guarantor in accordance with its terms, subject, as to
enforcement, to bankruptcy, insolvency, reorganization and other laws of general applicability relating to or affecting creditor’s rights. 


  

					
	Execution version – Hull No. 1688	 	Schedule VIII – Page 1	 	









 Each Guarantor hereby waives notice of any amendments, modifications or extensions of the Charter
and any other notices whatsoever provided under the Charter. Furthermore, this Guarantee shall not in any way be affected or prejudiced by: 
  

	 	(a)	any amendment to, renewal or variation or termination of the Charter made with or without notice to or the consent of the Guarantors; 


 

	 	(b)	any law, regulation or decree now or hereafter in effect in any jurisdiction which might in any manner affect any terms or provisions of the Charter or which might cause or permit to be invoked any alteration to the
time, amount or manner of performance by the Guarantors or the Owner of any of their obligations, whether or not the Guarantors shall have notice or knowledge of any of the foregoing; or 


 

	 	(c)	any misrepresentation by the Owner or either Guarantor, any lack of power or authority of the Owner to enter into or perform any of the obligations under the Charter or any failure of the Charter to constitute the
legal, valid and binding obligations of the Owner, enforceable in accordance with their terms. 

 Each Guarantor further agrees
that the Charterer and its successors and assigns may pursue, at its election, any remedy or remedies hereunder directly against the Guarantors without first proceeding against the Owner or any other person, or foreclosing on any security for, or
other guarantee of, the performance or payment of the obligations of the Owner. 
 Each Guarantor hereby irrevocably agrees that to the
extent that such Guarantor or any of its assets has or hereafter may acquire any right of immunity related to or arising from the transactions contemplated by this Guarantee, whether characterized as sovereign immunity or otherwise, from any legal
proceedings, to enforce or collect upon this Guarantee or any other liability or obligation of such Guarantor related to or arising from the transactions contemplated by this Guarantee, including, without limitation, immunity from service of
process, immunity from jurisdiction or judgement of any court or tribunal, immunity from execution of a judgement, and immunity of any of its property from attachment prior to any entry of judgement, or from attachment in aid of execution upon a
judgement, each Guarantor hereby expressly and irrevocably waives any such immunity. 
  

	4.	The obligations of the Guarantors hereunder shall not be subject to any counterclaim, set-off, reduction, deferment or defence (other than due performance and payment of the obligations of the Owner under the Charter or
any other defense available to the Owner under the Charter and/or at law). Any claims of the Guarantors or either of them against the Owner, whether arising from payments or performance by the Guarantors hereunder or otherwise, shall be subordinate
to the full and indefeasible payment and performance of the obligations generated hereunder. 

  

	5.	 This Guarantee shall not in any way be affected, reduced, limited, impaired, discharged, deferred, suspended, terminated or prejudiced by any change
in corporate structure, control or ownership of the Owner or either Guarantor, by any proceeding, voluntary or 



  

					
	Execution version – Hull No. 1688	 	Schedule VIII – Page 2	 	










	 	
involuntary, involving the bankruptcy, insolvency, receivership, reorganization, liquidation or arrangement of either of the Guarantors, the Owner or any other affiliate of either of the
Guarantors or other like procedure, or by any defence either Guarantor, the Owner or any other affiliate of either of the Guarantors may have by reason of the order, decree or decision of any court or administrative body resulting from any such
proceeding. 

  

	6.	No delay or omission by the Charterer in exercising any right hereunder shall operate as a waiver of such right or of any other right hereunder or under the Charter. If any payment of the Owner in respect of the Charter
is rescinded or must otherwise be returned for any reason whatsoever, the Guarantors shall remain liable hereunder as if such payment had not been made. 


Wherever possible, any provision in this Guarantee which is prohibited or unenforceable in any jurisdiction shall, as to such jurisdiction, be
ineffective only to the extent of such prohibition or unenforceability without invalidating the remaining provisions hereof, and any such prohibition or unenforceability in any one jurisdiction shall not invalidate or render unenforceable such
provision in any other jurisdiction. 
  

	7.	This Guarantee shall be binding on the Guarantors and their successors and assigns, and shall inure to the benefit of the Charterer and its successors and assigns. 


 

	8.	This Guarantee shall be governed by and construed in accordance with the laws of England. The foregoing notwithstanding, a person who is not a party to this Guarantee has no right under the Contracts (Rights of Third
Parties) Act 1999 to enforce any term of this Guarantee. Each Guarantor hereby irrevocably submits to the non-exclusive jurisdiction of the courts of England for purposes of any legal action or proceeding arising out of or in connection with this
Guarantee and waives any objection in such legal action or proceeding that the venue is improper or the forum is inconvenient. 

  

	9	Each Guarantor hereby irrevocably appoints the agent mentioned opposite its name in Schedule 1 hereto to accept service in England of any process on its behalf, except that a Guarantor may terminate such appointment if
prior thereto it delivers to the Charterer in writing the irrevocable appointment of a successor agent in London together with the acceptance of such appointment by the successor agent. 


 

	10.	The address of each Guarantor for the purposes of giving notices hereunder is as follows: 

  

			
	For Höegh:	  	
		
	Mail Address:	  	[                                      
  ]
		  	[                                      
  ]
		  	[                                      
  ]
		
	Office Address:	  	[                                      
  ]
		  	[                                      
  ]
		  	[                                      
  ]


  

					
	Execution version – Hull No. 1688	 	Schedule VIII – Page 3	 	










					
	Fax:	  		  	[                                      
  ]
	For Attention:	  		  	[                                      
  ]
		  		  	[                                      
  ]
			
	For MOL:	  		  	[                                      
  ]
		  	
[                          
              ] 

		  		  	[                                      
  ]
			
	Mail Address:	  		  	[                                      
  ]
		  		  	[                                      
  ]
		  		  	[                                      
  ]
			
	Office Address:	  		  	[                                      
  ]
		  	
[                          
              ] 

		  		  	[                                      
  ]
			
	Fax:	  		  	[                                      
  ]
	For Attention:	  		  	[                                      
  ]
		  		  	[                                      
  ]

  

	11.	Except as otherwise defined herein, all capitalized words and expression in this Guarantee shall have the same meanings as ascribed thereto in the Charter. 


EXECUTED AND DELIVERED as a DEED on this [—] day of
[—], 200[—]. 

  

					
	Execution version – Hull No. 1688	 	Schedule VIII – Page 4	 	









 EXECUTION PAGE 

 

			
	EXECUTED AND DELIVERED AS A DEED	  	)
	by Höegh LNG Ltd.	  	)
	acting by: [—]	  	)
	expressly authorised in accordance with	  	)
	the laws of [—]	  	)
	by virtue of a power of attorney granted	  	)
	by Höegh LNG Ltd.	  	)
	on [—]	  	)
	such execution being witnessed by:	  	)
	[name of witness]	  	)

 Signature of witness: 
  

			
	EXECUTED AND DELIVERED AS A DEED	  	)
	by Mitsui O.S.K. Lines, Ltd.	  	)
	acting by: [—]	  	)
	expressly authorised in accordance with	  	)
	the laws of [—]	  	)
	by virtue of a power of attorney granted	  	)
	by Mitsui O.S.K. Lines, Ltd.	  	)
	on [—]	  	)
	such execution being witnessed by:	  	)
	[name of witness]	  	)

 Signature of witness: 

  

					
	Execution version – Hull No. 1688	 	Schedule VIII – Page 5	 	









 Schedule to Deed of Guarantee 

 

			
	Name of Guarantor	  	Name and Address of Agent in England
		
	Höegh	  	[—]
		
		  	[—]
		
		  	For Attention: [—]
		
	Name of Guarantor	  	Name and Address of Agent in England
		
	MOL	  	[—]
		
		  	[—]
		
		  	For Attention: [—]


  

					
	Execution version – Hull No. 1688	 	Schedule VIII – Page 6	 	









 SCHEDULE IX 

TO 
 SRV LNG CARRIER
TIME CHARTER PARTY 
 DATED MARCH 2007 

Form of Ownership Undertaking 

[Letterhead of Suez SA] 
 SRV Joint Gas
limited 
 [address] 
 [Date] 

Dear Sirs 
 Time Charter in respect of one Shuttle and
Regasification Vessel currently having hull no. 1688 at Samsung Heavy Industries Co., Ltd. 
 We refer to the time charter (the “Charter”) of even
date herewith and entered into between SRV Joint Gas Limited (the “Owner”) and Suez LNG Trading SA (the “Charterer”) relating to the Vessel. 

Unless the context requires otherwise, words and expressions defined in the Charter shall have the same meanings when used in this letter. 

In accordance with Clause 14(e)(ii) of the Charter, this Ownership Undertaking shall be effective only upon effectiveness of the Charter and waiver or
satisfaction of all conditions precedent in Clause 76 of the charter. 
 The Charterer is at the date hereof an indirect wholly-owned subsidiary of Suez SA.

  

	1.	By this letter, and in satisfaction of, and as a condition to, the Owner entering into the Charter, Suez SA, hereby confirms that, for so long as the Charterer shall be under any obligation (actual or contingent) under
the Charter, if at any time we intend to take, or permit to be taken by any other subsidiary of ours, any action which would result in the Charterer ceasing to be a direct or indirect wholly-owned subsidiary of Suez SA, its successors or assigns, we
will notify the Owner in writing of such intent as well as the name of the party (the “Acquirer”) to whom we intend to transfer, or permit to be transferred, our direct or indirect interest in the Charterer. 


In this letter “wholly-owned subsidiary of Suez SA” shall mean a subsidiary of which Suez SA owns and controls at least 99% of the
voting stock issued and outstanding as of the date hereof. 

  

					
	Execution version – Hull No. 1688	 	Schedule IX – Page 1	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	2.	Not later than ***** days following receipt by the Owner of our written notice, the Owner shall notify us in writing as to whether, acting reasonably, it has determined that any of the three criteria set forth in Part A
of the Appendix to this letter apply. If the Owner determines that none of the criteria set forth in Part A of the Appendix apply, or if the Owner fails to respond to our notice within said *****-day period, then we shall thereafter be free to
effect such transfer so long as we do so in accordance with our notice to the Owner as originally given. If the Owner, acting reasonably, determines that one or more of the criteria set forth in Part A of the Appendix apply and the Owner so notifies
us in writing within said *****-day period, then such transfer may thereafter be effected only upon satisfaction of one of following two conditions: 

  

	 	(a)	Suez SA shall procure that the rights and obligations of the Charterer under the Charter and the related documents to which the Charterer is a party are transferred to another direct or indirect wholly-owned subsidiary
of Suez SA (or any of its successors), which has financial substance acceptable to the Owner and its financiers holding Permitted Encumbrances (each acting reasonably); or 


 

	 	(b)	Suez SA shall procure that the conditions set forth in Part B of the Appendix, to the extent same are required by the Owner to be satisfied as indicated in the Owner’s written notice, are fully satisfied.


  

	3.	Provided the Owner’s notice is timely received under the terms of Paragraph 2 above, we undertake to comply or procure compliance with, at our sole discretion, either the Owner’s requirement pursuant to
Paragraph 2(a) above or the conditions referred to in Paragraph 2(b) above, prior to effecting or permitting such a transfer of our direct or indirect interest in the Charterer and undertake that such a transfer shall not otherwise occur.


  

	4.	The effect of any transfer of the rights and obligations of the Charterer under the Charter and the related documents to which the Charterer is a party to another direct or indirect wholly-owned subsidiary of Suez SA
(or any of its successors) shall not cause the Owner to suffer or incur any greater cost in the performance of its obligations under the Charter other than would have been the case but for such transfer. The provisions of this letter shall apply
equally to any direct or indirect wholly-owned subsidiary of Suez SA (or any of its successors) to whom such rights and obligations are transferred and references to the “Charterer” shall be construed accordingly. 


 

	5.	This letter shall be governed by and construed in accordance with English law and shall constitute our legally enforceable rights and obligations. 


  

					
	Execution version – Hull No. 1688	 	Schedule IX – Page 2	 	









 Please indicate your agreement to the matters set out in this letter by executing the form of acknowledgement set
out below. 
 Yours faithfully 
  

	
	  

	 For and on behalf of
 Suez SA

	
	Acknowledged and agreed
	
	  

	 For and on behalf of
 SRV Joint Gas
Limited



  

					
	Execution version – Hull No. 1688	 	Schedule IX – Page 3	 	









 APPENDIX 

A. Criteria for Imposing Conditions 
  

	1.	The Acquirer or any Affiliated Company of the Acquirer is involved in an actual or threatened legal dispute or arbitration with the Owner or any Affiliated Company of the Owner. For purposes of this Appendix,
“threatened legal dispute or arbitration” means any dispute in respect of which either the Acquirer or any Affiliated Company of the Acquirer has indicated in writing that it intends to issue or commence legal or arbitration proceedings
against the Owner or any Affiliated Company of the Owner. 

  

	2.	It would be unlawful or contrary to applicable sanctions affecting the Owner or any Affiliated Company of the Owner for the Owner to charter to the Charterer as a subsidiary of the Acquirer. 


 

	3.	The Acquirer or a relevant Affiliated Company of the Acquirer has not, in the Owner’s reasonable opinion, the experience and financial substance required to enable the Charterer, under its new ownership or control,
to fulfill the obligations of the Charterer under the Charter. 

 B. Permissible Conditions 

 

	1.	A guarantee (in substantially the same form as the guarantee of the Owner’s guarantor(s)) or other support on terms acceptable to the Owner (acting reasonably) shall be provided for the Charterer’s obligations
and the creditworthiness of the party providing such guarantee or other support shall be satisfactory to the Owner or the Owner’s financiers holding Permitted Encumbrances (each acting reasonably). 


 

	2.	Neither the Acquirer nor any Affiliated Company of the Acquirer is involved in an actual or threatened legal dispute or arbitration with the Owner or any Affiliated Company of the Owner. For purposes of this Appendix,
“threatened legal dispute or arbitration” means any dispute in respect of which either the Acquirer or any Affiliated Company of the Acquirer indicated in writing that it intends to issue or commence legal or arbitration proceedings
against the Owner or any Affiliated Company of the Owner. 

  

	3.	All necessary and appropriate changes, if any, shall be made to comply with any applicable law and/or sanction affecting the Owner that, but for such changes, would make the Owner’s or an Affiliated Company of the
Owner’s charter of the Vessel to a subsidiary of the Acquirer unlawful or contrary to any such sanctions. 

  

	4.	The Acquirer or a relevant Affiliated Company of the Acquirer shall demonstrate to the Owner’s reasonable satisfaction that it has the experience and financial substance required to enable the Charterer, under its
new ownership or control, to fulfil the obligations of the Charterer under the Charter. 


  

					
	Execution version – Hull No. 1688	 	Schedule IX – Page 4	 	









 SCHEDULE X 

TO 
 SRV LNG CARRIER
TIME CHARTER PARTY 
 DATED MARCH 2007 

GAS NOMINATION PROCEDURES 
 This Schedule
X outlines the principles governing Owner’s and Charterer’s notifications and nominations of gas dispatch volumes from the Terminal (which, for purposes of this Schedule X, shall mean the Deepwater Port whenever one or two Vessels are
moored at the Deepwater Port) to the Downstream Systems, as may be amended from time to time to be consistent with industry practice (hereinafter the “Gas Nomination Procedures”). 

A separate document detailing the actual gas nominations procedures for the Terminal shall be agreed based on these principles. 

It is noted that Charterer is solely responsible for the acquisition and/or control of pipeline transportation capacity sufficient to carry out its desired
trade and to accept and transport in the Downstream Systems any and all gas volumes nominated by Charterer for delivery from the Terminal. Such acquisition of pipeline transportation or capacity reservations or other means of securing the take-away
of such nominated gas volumes is solely for the account and risk of Charterer. “Commercial Operations” shall mean representative(s) of Charterer responsible for the overall management and scheduling of the nominated dispatch volumes on the
Downstream Systems and related procedures as outlined in, but not limited to, this Schedule X. 
  

	1.	Yearly nominations protocols: For maintenance planning purposes and to facilitate scheduled maintenance of the Vessel and the Buoy System and Downstream Systems, Owner and Charterer will meet each year to establish a
yearly nomination protocol in order to coordinate and optimize any scheduled maintenance of the Buoy System, Downstream Systems and SRVs that may impact gas nominations. This meeting shall occur not later than August 30 (in connection with the
yearly budget) each year. 

  

	2.	Rolling 1-month and 1-week nominations protocol: Based on the yearly nomination protocol, a rolling 1-month protocol and 1-week protocol shall be established and updated weekly as a tool to plan Vessel movement and
short notice maintenance planning. 

  

	3.	 Vessels: The longest moored Vessel to the Deepwater Port is the “Vessel On Station” and is responsible for the Terminal’s send-out and
all communication with Commercial Operations. Commercial Operations communicates with and sends notices of its Nominated Discharge Rate and Intraday Nominations only to the Charterer’s designated representative (“Charterer’s
Representative”) onboard the “Vessel on Station”, who in turn will relay the Nominated Discharge Rates in written format to the master of the Vessel On Station. Any Vessel that is approaching the Deepwater Port is an “Arriving
Vessel” and will remain so also when securely moored to the Deepwater Port and during 



  

					
	Execution version – Hull No. 1688	 	Schedule X – Page 1	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
discharge of gas if there already is a Vessel On Station. When the Vessel On Station departs the Deepwater Port, the remaining Vessel becomes the Vessel On Station. If no Vessel is at the
Deepwater Port, then Commercial Operations communicates and sends notices to the master of the nearest Arriving Vessel, which when securely moored to the Deepwater Port becomes the Vessel on Station. 


 

	4.	Inbound voyage: After departure from a Loading Terminal of a Vessel scheduled to be an Arriving Vessel, the following actions shall be undertaken: 


 

	 	a.	The master of the Arriving Vessel will consult the last rolling nominations protocols and contact the Vessel On Station to receive the date and time of the anticipated end of the offloading cycle of the Vessel On
Station, and then send Notices of Arrival (NOA) in accordance with the SRV Operations Manual or specific voyage instructions to provide an indication of the Expected Time of Arrival (ETA) at the Deepwater Port and the expected time of notification
of Readiness to Discharge Gas. The specific voyage instructions shall be performed in addition to the SRV Operations Manual and in the event such instructions conflict with a procedure in the SRV Operations Manual, shall supersede the conflicting
procedure in the SRV Operations Manual. 

  

	 	b.	Commercial Operations will, within ***** hours of receiving the first NOA from the Arriving Vessel, respond by providing notification to the Arriving Vessel of the expected discharge profile for the impending offloading
cycle including any currently anticipated periods where a nomination will be submitted requesting a discharge rate in excess of the Normal Performance rate applicable to the Discharge Period as noted in Article 11 of Appendix I to Schedule I.


  

	 	c.	The master of the Arriving Vessel will, within ***** hours of receiving the notification under (b) above, states its readiness to make available vaporization capacity to meet the expected discharge profile.


  

	5.	Updated notifications: Commensurate with the 24 hour ETA notice. 

  

	 	a.	The master of the Arriving Vessel shall notify Commercial Operations in written form of the expected time of Readiness to Discharge Gas (“***** Hour Notice”) and (with such continuation not affecting
performance requirements under the Charter) confirm the vaporization capability for the impending offloading cycle. 

  

	 	b.	Commercial Operations shall, within ***** hours of receiving the ***** Hour Notice, provide in writing to the Charterer’s Representative onboard the Vessel On Station (if any) and the Arriving Vessel the expected
discharge profile for the impending offloading cycle. 

  

	6.	 Arrival: The master of the Arriving Vessel shall provide a written notice to the Neptune Port Director of its Arrival at the Deepwater Port. For
purposes of this Schedule X, “Arrival” shall mean the time when the Arriving Vessel is ***** nautical miles off the Deepwater Port and waiting to be cleared by the Neptune Port Director (having submitted a request for clearance) to enter
the safety zone to moor to the Buoy System and prepare to discharge gas from the Terminal. 



  

					
	Execution version – Hull No. 1688	 	Schedule X – Page 2	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
Commercial Operations may provide a Nominated Discharge Rate to the Arriving Vessel prior to the notice of Readiness to Discharge Gas if it is anticipated that it will be able to discharge gas
for a Gas Day for which a nomination would normally be made under Clause 5 of this Schedule X. 

  

	7.	Readiness to Discharge: Subsequent to receiving clearance notification from the Neptune Port Director, a written notice of “Readiness to Discharge Gas” shall be given by the master of the Arriving Vessel to
Commercial Operations and the Vessel on Station (if any) upon the earliest occurrence of the following conditions: 

  

	 	a.	The Arriving Vessel is moored and is ready in all respects to discharge gas; OR 

  

	 	b.	The Arriving Vessel has received clearance to enter the Deepwater Port and ***** hours have passed since such notice was given, unless such time is extended by reasons attributable to Charterer, the Neptune Port
Director, governmental or regulatory authorities, or Force Majeure. 

 For purposes of this Schedule X, “Force
Majeure” shall mean any act or event that prevents or delays the Arriving Vessel from being ready in all respects to discharge gas, including any act or event arising in connection with the Downstream Systems that affects the discharge
operations of the Vessel on Station, if and to the extent such act or event is beyond Owner’s reasonable control, not the result of Owner’s fault or negligence, and Owner has been unable to overcome the consequences of such act or event by
the exercise of reasonable efforts. Subject to the satisfaction of the conditions established in the previous sentence, Force Majeure shall include the following acts or events which prevent or delay the Arriving Vessel from being ready in all
respects to discharge gas, including any act or event arising in connection with the Downstream Systems that affects the discharge operations of the Vessel on Station: (i) natural phenomena and acts of God, such as storms, floods, lightning and
earthquakes; (ii) fires; (iii) wars, civil disturbances, riots, insurrections and sabotage; (iv) strikes or other labor disputes that are not due to the breach of a labor contract by Owner or any of its contractors; and
(v) actions of a governmental entity or agency, or national, port or other local authority having jurisdiction over the Vessel or the Buoy System. 
  

	8.	Daily nominations protocol: 

  

	 	a.	Commercial Operations, via the Charterer’s Representative onboard, provides the Vessel On Station (i) a Nominated Discharge Rate (in a form to be agreed) for the next day’s Gas Day (which commences at
10:00 AM Boston local time the following day) and (ii) in the case of a discharge for a partial Gas Day, the hours for which such discharge will take place, in either case by 12:00 PM Boston local time. 


 

	 	b.	 The master on the Vessel On Station shall, within ***** hours of receiving the Nominated Discharge Rate from the Charterer’s Representative,
notify the 



  

					
	Execution version – Hull No. 1688	 	Schedule X – Page 3	 	










 SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN
REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****). 

 


	 	
Charterer’s Representative if the Terminal can meet such Nominated Discharge Rate and the number of hours of send-out remaining at such discharge rate. If the Terminal is unable to comply
with the Nominated Discharge Rate, then the master shall state the reason for the deviation and the volume that the Terminal is able to provide as a discharge rate. 


 

	 	c.	With ***** hours of discharge at the Nominated Discharge Rate remaining onboard the Vessel On Station, the Terminal will commence overlap operations if there is an Arriving Vessel moored at or approaching the Deepwater
Port. 

  

	9.	Intraday Nominations: Any nomination that would change the Nominated Discharge Rate that would otherwise be submitted under Paragraph 8 of this Schedule X shall be considered an “Intraday Nomination”. Intraday
Nominations may occur while the Terminal is discharging pursuant to the following: 

  

	 	a.	Commercial Operations shall submit a written Intraday Nomination (in a form to be agreed) to the Vessel on Station via the Charterer’s Representative onboard to communicate changes to the current Nominated
Discharge Rate. 

  

	 	b.	The master of the Vessel on Station shall confirm to the Charterer’s Representative, within ***** hour of receipt of such notice, the intraday changes that the Terminal is able to undertake and the timing of the
implementation of such Intraday Nomination. 

  

	10.	Coordination with the pipeline operator: The Charterer shall be responsible for all downstream pipeline nominations and transportation as required, and will have direct interaction with the pipeline operator regarding
such matters. All required communications to and from the pipeline operator to the Vessel on Station shall be communicated via the Charterer’s Representative to the master of the vessel (provided that in a case of emergency when
Charterer’s Representative is not present or reachable, then the master of the Vessel on Station may make toor receive from the pipeline operator directly necessary communications). 


 

	11.	Interruption of accepted Nominated Discharge Rate. 

  

	 	a.	In the event that the discharge operations of the Terminal are interrupted for a material period for any reason attributable to the actions of the Terminal, the master of the Vessel on Station shall notify the
Charterer’s Representative onboard and such notification shall include all relevant information including (i) the aggregate impact on the discharge of gas for the relevant Gas Day, (ii) the nature of the interruption detailing, if
available, the cause of the interruption, and (iii) the anticipated duration of the interruption if such information is available at the time of the initial notification. 


 

	 	b.	In the event that the Terminal is to curtail operations for unplanned reasons attributable to the instructions of Charterer, Charterer will immediately submit an Intraday Nomination. 


  

					
	Execution version – Hull No. 1688	 	Schedule X – Page 4	 	









 SCHEDULE XI 

TO 
 SRV LNG CARRIER
TIME CHARTER PARTY 
 DATED MARCH 2007 

NOTICE UNDER CLAUSE 76 RE LIFTING OF SUBJECTS 

Form of Charterer’s Notice 

[Letterhead of Charterer] 
 SRV Joint Gas
Limited 
 Höegh LNG AS 
 Drammensveien 134 

P.O. Box 4 Skøyen 
 0121 Oslo, Norway 

Fax no.: +47 21039013 
 Attention: Executive Vice-President 

With a copy to: 
 Mitsui O.S.K. Lines, Ltd. 

1-1, Toranomon 2-Chome, Minato-ku 
 Tokyo 105-8688 Japan 

Fax n.: +81-3-3587-7737 
 Attention: General Manager, LNG Carrier
Division 
 Dear Sirs, 
 SRV LNG Carrier Time Charterparty
dated [                    ] (the “Charter”) 

We refer to the Charter between us relating to one 145,000m3 liquefied natural gas (LNG) shuttle and
regasification vessel, with Builder’s Hull No. 1688 and hereby notify you pursuant to Clause 76 of the Charter that we have received all corporate approvals necessary to make the Charter effective. 

We further confirm that the condition precedent under Clause 76 has thereby been satisfied. 

 

	
	Yours faithfully
	
	  

	For and on behalf of
	Suez LNG Trading SA


  

					
	Execution version – Hull No. 1688	 	Schedule XI – Page 1	 	









 Date 25 March 2010 

GDF SUEZ LNG TRADING SA 
 -
and - 
 GDF SUEZ GLOBAL LNG SUPPLY SA 

- and - 
 SRV JOINT GAS LTD

  
  

NOVATION AGREEMENT 
  

 
 in respect of
Hull No. 1688 







 THIS AGREEMENT is made on 25 March 2010 

BETWEEN: 
  

	(1)	GDF SUEZ LNG TRADING SA, (formerly called Suez LNG Trading SA) a company incorporated under the laws of Luxembourg having its registered office at 76 avenue de la Liberté, L-1930 Luxembourg and registered
with the Luxembourg trade and companies register under number B85242 (the “Existing Charterer”); 

  

	(2)	SRV JOINT GAS LTD, a company incorporated under the laws of the Cayman Islands (the “Owner”); and 

  

	(3)	GDF SUEZ GLOBAL LNG SUPPLY SA, a company incorporated under the laws of Luxembourg having its registered office at 76 avenue de la Liberté, L-1930 Luxembourg and registered with the Luxembourg trade and
companies register under number B147797 (the “New Charterer”). 

 WHEREAS: 

 

	(A)	The Existing Charterer and the Owner have entered into a SRV LNG carrier time charterparty dated 20 March 2007 in respect of Hull No. 1688 under construction at Samsung Heavy Industries Co., Ltd.


  

	(B)	The parties have agreed that the said charterparty is to be novated from the Existing Charterer to the New Charterer on the terms and conditions set out below. 


NOW IT IS HEREBY AGREED as follows: 
  

	1.	DEFINITIONS 

  

	1.1	Words and expressions defined in the Charterparty shall have the same meanings when used in this Agreement. 

  

	1.2	In this Agreement: 

 “Charterparty” means the SRV LNG carrier time charterparty
first referred to in recital (A) above; 
 “Effective Time” means the time at which the novation pursuant to this Agreement
takes effect being the time to be specified in the Effective Time Certificate; 
 “Effective Time Certificate” means the
certificate to be executed by the parties to this Agreement and by the Lenders’ Agent pursuant to Clause 2.2 in the form set out in Appendix 1; 

“Lenders’ Agent” means DnB NOR Bank A.S.A.; 

“Novated Obligations” means all the obligations expressed to be imposed on the Existing Charterer finder or in connection with
the Charterparty; and 
 “Novated Rights” means all the rights expressed to be granted to the Existing Charterer under or in
connection with the Charterparty. 

  
 1 









	2.	NOVATION 

  

	2.1	The Existing Charterer agrees to novate the Charterparty to the New Charterer, and the Owner consents to such novation, on and with effect from the Effective Time, upon the following terms and conditions:


  

	 	(a)	the Existing Charterer releases and discharges the Owner from its obligations to the Existing Charterer in respect of the Novated Rights; 


 

	 	(b)	the Existing Charterer is released and discharged from the Novated Obligations; 

  

	 	(c)	the New Charterer shall have the benefit of the Novated Rights to the exclusion of the Existing Charterer (and accordingly the Owner undertakes to perform its obligations in respect of the Novated Rights under the
Charterparty in favour of the New Charterer); and 

  

	 	(d)	the New Charterer shall assume the Novated Obligations, 

 such that with effect from the
Effective Time the New Charterer shall be substituted in place of the Existing Charterer as a party to the Charterparty and the Charterparty shall, on and with effect from the Effective Time, be construed and treated, and the Owner shall be bound by
the Charterparty, in all respects as if the New Charterer were named therein as “Charterer” in place of the Existing Charterer. For the avoidance of doubt, the novation of the Novated Rights and the Novated Obligations from the Existing
Charterer to the New Charterer in accordance with this Agreement shall not operate to affect or diminish, as against the New Charterer, the rights which the Owner had against the Existing Charterer immediately prior to the Effective Time and the
rights which the Owner would have had against the Existing Charterer but for the occurrence of the Effective Time. 
  

	2.2	The parties agree to execute the Effective Time Certificate (and, the Owner agrees to procure the execution by the Lenders’ Agent of the Effective Time Certificate) promptly upon each of the parties having received
the applicable following documents or evidence satisfactory to it: 

  

	 	(a)	the New Charterer has received an Owner’s Guarantee from the Owner’s Guarantors covering the obligations of the Owner under the Charterparty, in replacement for the existing Owner’s Guarantee;


  

	 	(b)	the Charterer has received a new tripartite agreement executed by the Builder, the Existing Owner, the Charterer, Neptune LNG LLC and the New Owner in replacement for the existing tripartite agreements dated
20 December 2007 executed by the Builder, Neptune LNG LLC and the Existing Owner; 


  
 2 









	 	(c)	the Owner has received a comfort letter from GDF Suez SA, in replacement for the existing comfort letter issued by GDF Suez SA in favour of the Owner; 


 

	 	(d)	the Owner has received an ownership undertaking from GDF Suez SA in respect of the New Charterer, in replacement for the existing ownership undertaking issued by GDF Suez SA in favour of the Existing Charterer;


  

	 	(e)	the Owner has received an information sharing letter from the New Charterer, in replacement for the existing information sharing letter issued by the Existing Charterer in favour of the Owner; 


 

	 	(f)	the Existing Charterer and the Owner, respectively, receive evidence satisfactory to them that the obligations of the Owner and the Owner’s Guarantors (in the case of the New Charterer) and of the New Charterer and
GDF Suez SA (in the case of the Owner) under the documents referred to above which are to be replaced have been duly released by the beneficiary of those obligations; 


 

	 	(g)	a new consent and agreement has been executed by the Owner, the New Charterer and the Lenders’ Agent in replacement for the existing consent and agreement executed by the Owner, the Existing Charterer and the
Lenders’ Agent; 

  

	 	(h)	the Lenders’ Agent has received: 

  

	 	(i)	an amendment to the facility agreement between the Owner and the Lenders’ Agent and a new security assignment executed by the Owner in favour of the Lenders’ Agent, together with supporting corporate
authorities and a favourable legal opinion on Cayman Islands law (which amendment and new security assignment the Owner undertakes to execute promptly after execution of this Agreement); and 


 

	 	(ii)	a favourable legal opinion on Luxemburg law in relation to the execution by the New Charterer and the Existing Charterer of the new consent and agreement referred to in Clause 2.2(g). 


 

	 	(i)	evidence satisfactory to each party, acting reasonably, of the due authorisation and execution by the other party (and other relevant parties) of the documents referred to in Clauses 2.2(a), (b), (c), (d), (e),
(f) and (g). 

  

	2.3	The new documents referred to in Clauses 2.2(a), (b), (c), (d), (e), (g) and (i) shall be in the same form as the documents which they replace with only consequential amendments to reflect the novation of the
Charterparty from the Existing Charterer to the New Charterer. 


  
 3 









	3.	AMENDMENTS TO THE CHARTERPARTY 

  

	3.1	On and with effect from the Effective Time, the Charterparty shall be read and construed in all respects as if: 

  

	 	(a)	references therein to the Existing Charterer as “Charterer” were references to the New Charterer; 

  

	 	(b)	references therein to “this Charter”, “herein”, “hereof” or any similar expressions were references to the Charterparty as novated and amended by this Agreement; and 


 

	4.	REPRESENTATIONS AND WARRANTIES 

  

	4.1	Each party represents and warrants to the other that it has legal capacity to enter into this Agreement and that this Agreement has been duly executed by it and constitutes its legally valid and binding obligations.


  

	5.	FURTHER ASSURANCES 

  

	5.1	Each party shall execute such documents and take such action as any other party shall reasonably request as being necessary to implement the transactions and matters contemplated by this Agreement. 


 

	6.	COSTS 

  

	6.1	Each page shall bear its own costs in connection with the negotiation, preparation, execution and implementation of this Agreement. 


 

	7.	THIRD PARTY RIGHTS 

  

	7.1	Subject as referred to below, no person who is not a party to this Agreement shall have any rights under it by reason of the Contracts (Rights of Third Parties) Act 1999. However, it is agreed for the benefit of the
Lenders’ Agent that the novation of the Charterparty by the Existing Charterer to the New Charterer by this Agreement shall not take effect unless the Lenders’ Agent has executed the Effective Time Certificate in accordance with Clause 2.2
and that the terms of this Agreement cannot be waived, varied or amended by the parties in a manner inconsistent with the foregoing without the prior written consent of the Lenders’ Agent. 


 

	8.	COUNTERPARTS 

  

	8.1	This Agreement may be executed in several counterparts and any single counterpart or set of counterparts signed, in either case, by all of the parties thereto shall be deemed to be an original, and all counterparts when
taken together shall constitute one and the same instrument. 

  

	9.	GOVERNING LAW AND ARBITRATION 

  

	9.1	This Agreement, and all non-contractual obligations arising out of this Agreement, shall be governed by, and construed in accordance with, English law. 


 

	9.2	The arbitration provisions of clause 53 of the Charterparty shall apply to any dispute arising out of this Agreement. 


  
 4 








 IN WITNESS WHEREOF this Agreement has been executed by the parties the day and year first above written.

  

					
	SIGNED by	  	)	  	/s/ JEAN-CHARLES PAPEIANI
	Jean-Charles Papeiani	  	)	  	
	for and on behalf of	  	)	  	
	GDF SUEZ LNG TRADING SA	  	)	  	
	in the presence of:	  	)	  	
	DN Osborne	  		  	
	London EC2 (Solicitor)	  		  	
			
	SIGNED by	  	)	  	/s/ MATTHEW LEIGH,
	Matthew Leigh	  	)	  	Matthew Leigh
	for and on behalf of	  	)	  	Attorney-in-fact
	SRV JOINT GAS LTD	  	)	  	
	in the presence of:	  	)	  	
	Martin Scholter	  		  	
	15 Appold Street London EC2A 2HB	  		  	
			
	SIGNED by	  	)	  	/s/ KEVIN KIRBY
	Kevin Kirby	  	)	  	Managing Director
	for and on behalf of	  	)	  	
	GDF SUEZ GLOBAL LNG SUPPLY SA	  	)	  	
	in the presence of:	  	)	  	
	/s/ MATTHEW LEIGH	  		  	Matthew Leigh
	Matthew Leigh,	  		  	Solicitor
	Attorney-fact	  		  	London EC2A 2HB


  
 5 








 APPENDIX 1 

FORM OF EFFECTIVE TIME CERTIFICATE 

Reference is made to the Novation Agreement dated [—] 2010 (which is the Effective Time Certificate
referred to in the said Novation Agreement). 
 It is hereby confirmed that the Effective Time is     m (London time) on [—] 2010. 
  

	
	  

	for and on behalf of
	SRV JOINT GAS LTD
	
	  

	for and on behalf of
	GDF SUEZ LNG TRADING SA
	
	  

	for and on behalf of
	GDF SUEZ GLOBAL LNG SUPPLY SA
	
	  

	for and on behalf of
	DnB NOR BANK A.S.A.


  
 6