In the United States Court of Federal Claims

No. 18-1943C

(Filed: August 11, 2020)

HCIC ENTERPRISES, LLC,

d/b/a HCI GENERAL CONTRACTORS,

Plaintiff,

v.

THE UNITED STATES,

Defendant.

)

)

)

)

)

)

)

)

)

)

)

)

)

Keywords: Failure to State a Claim; 

RCFC 12(b)(6); Sua Sponte; Contracting 

Officer Final Decision

 

Frank V. Reilly, Fort Lauderdale, FL, for Plaintiff.

Robert C. Bigler, Trial Attorney, Commercial Litigation, Civil Division, U.S. Department of 

Justice, Washington, DC, for Defendant, with whom were Steven J. Gillingham, Assistant 

Director, Robert E. Kirschman, Jr., Director, Joseph H. Hunt, Assistant Attorney General. 

ORDER

KAPLAN, Judge.

This case—which is before the Court on its order to show cause why the complaint 

should not be dismissed—involves a contract to repair roofs at the Federal Correctional 

Institution in Estill, South Carolina (“FCI Estill”).

1 In its initial complaint, Plaintiff HCIC 

Enterprises, LLC (“HCIC”) alleged that the Federal Bureau of Prisons (“FBOP”) breached the 

contract when it failed to provide HCIC’s crews “access” to the worksite. Before the agreedupon discovery period closed, HCIC filed a motion for summary judgment (which it styled a 

motion for judgment on the pleadings), and to which the government responded by filing its own

cross-motion for partial summary judgment concerning an issue of contract interpretation.

After holding oral argument, the Court denied HCIC’s motion for summary judgment and 

granted the government’s cross-motion. It held that contractual provisions promising HCIC 

 1 The Court has set forth a more detailed recitation of the relevant facts in its previous orders. 

See generally HCIC Enters., LLC v. United States, 147 Fed. Cl. 118 (2020) (denying HCIC’s 

motion for summary judgment and granting the government’s cross-motion for partial summary 

judgment); HCIC Enters., LLC v. United States, 2020 WL 4197996 (Fed. Cl. July 9, 2020) 

(denying HCIC’s second motion to amend its complaint). 
2

“access” to the worksite must be read in light of applicable security requirements. Those 

requirements dictated that HCIC’s workers must be accompanied by prison escorts while at FCI 

Estill, and which stated that FBOP was only required to make two escorts available for that 

purpose. Id.

In the meantime, HCIC filed a motion to amend its complaint the day before the Court 

ruled on the cross-motions. See ECF No. 27. Then, the day before the government’s response to 

that motion was due, HCIC filed a second motion to amend. See ECF No. 29. 

The Court denied HCIC’s first motion to amend on mootness grounds. It subsequently

denied HCIC’s second motion to amend on July 9, 2020, because none of the claims HCIC set 

forth in its proposed amended complaint would survive a motion to dismiss. The Court ordered 

HCIC to show cause why its initial (and still operative) complaint should not be dismissed 

pursuant to Rule 12(b)(6) of the Rules of the Court of Federal Claims (“RCFC”). 

HCIC filed a response to the Court’s show cause order on July 27, 2020. In it, HCIC 

presents several new theories of recovery: 1) that the government and not HCIC “controlled the 

schedule” so that “the delay [in completion of the roofing repairs] was beyond HCIC’s control as 

a matter of law”; 2) that HCIC has a claim under the differing site conditions clause because “a 

review of the physical conditions at the jobsite prior to bid did not plainly reveal that the FBOP’s 

required 12-month project duration was impossible”; and 3) that FBOP constructively changed 

the contract by extending its duration beyond the original one-year performance period. Pl.’s 

Resp. to This Ct.’s July 9, 2020 Order to Show Cause (“Show Cause Resp.”) at 4–7, ECF 

No. 38. 

At the outset, the Court notes that because none of the claims HCIC presents in its 

response are in the operative (original) complaint, its response does not comply with the Court’s 

show cause order. That order, as noted, required HCIC to explain why its initial complaint 

should not be dismissed, sua sponte, for failure to state a claim. Further, even assuming HCIC 

were to file yet another motion to amend the original complaint, and assuming the Court were 

willing to entertain it, none of HCIC’s new contentions would survive a motion to dismiss.

For example, HCIC argues that its project delays were “excusable and compensable”

because FBOP has supposedly “successfully argued as a matter of law that it controlled the

schedule and that HCIC did not.” Id. at 4. (emphasis removed). The Court does not follow this 

argument; this Court never held that HCIC “controlled the schedule.” It determined that under 

the contract HCIC’s crews “could only work on one roof at a time, with one escort on the roof 

and one on the ground.” HCIC Enters., 147 Fed. Cl. at 125. Therefore, it held, to the extent that 

the delays were caused by enforcement of the security requirements, HCIC was not entitled to an 

equitable adjustment of the performance period or the contract price.

Second, HCIC has never made factual allegations that would support a claim based on

FAR 52.236-2 (entitled “differing site conditions”). See Show Cause Resp. at 3. It has never

alleged that delays in the project were caused by “subsurface or latent physical conditions at the 

site which differ materially from those indicated in this contract,” or “unknown physical 

conditions at the site, of an unusual nature, which differ materially from those ordinarily 

encountered and generally recognized as inhering in work of the character provided for in the 
3

contract.” FAR 52.236-2. Nor has it identified what the alleged “latent” or “unknown” physical 

conditions were that precluded it from timely completing performance. Indeed, to date, the only 

specific FBOP action that HCIC has contended caused performance delays was FBOP’s 

enforcement of its security requirements.

HCIC’s constructive change claim (as well as its “cardinal change” argument) similarly

appear to have no factual or legal basis. As HCIC did in its motion for summary judgment, HCIC

simply regurgitates boilerplate legal propositions without tying them to any supporting factual 

allegations. See HCIC Enters., 147 Fed. Cl. at 124 (observing that HCIC “does not identify what 

it claims are the undisputed facts and therefore cannot explain how the application of the legal 

standards it recites entitles it to judgment as a matter of law”).

Nor does it appear that HCIC ever presented the claims it is floating in its response to the 

show cause order to the contracting officer. This Court therefore would lack jurisdiction to 

consider them under the Contract Disputes Act. See 41 U.S.C. § 7104; M. Maropakis Carpentry, 

Inc. v. United States, 609 F.3d 1323, 1327 (Fed. Cir. 2010) (citing James M. Ellett Constr. Co. v. 

United States, 93 F.3d 1537, 1541–42 (Fed. Cir. 1996)) (explaining that a court’s exercise of 

jurisdiction over a Contract Disputes Act claim “requires both a valid claim and a contracting 

officer’s final decision on that claim”). 

In short, this Court’s decision granting the government’s motion for partial summary 

judgment effectively disposed of the sole discernible claim in HCIC’s original complaint, i.e.,

that HCIC was entitled to an equitable adjustment of the performance period and contract price 

because FBOP had breached the contract by refusing to provide HCIC “access” to the worksite.

Compl. ¶¶ 13, 15, ECF No. 1. Further, HCIC has now failed on multiple occasions to provide 

facts and a theory that would support any other claim or claims that could withstand a motion to 

dismiss under either RCFC 12(b)(1) or 12(b)(6). 

CONCLUSION

For the foregoing reasons, the Plaintiff’s complaint is DISMISSED with prejudice

pursuant to RCFC 12(b)(6) for failure to state a claim. The Clerk is directed to enter judgment 

accordingly. Each side shall bear its own costs.

IT IS SO ORDERED.

s/ Elaine D. Kaplan 

ELAINE D. KAPLAN

Judge