Filed 10/17/23 Neal Electric Corp. v. Clark Construction Group CA4/1 NOT TO BE PUBLISHED IN OFFICIAL REPORTS

California Rules of Court, rule 8.1115(a), prohibits courts and parties from citing or relying on opinions not certified for publication or ordered published, except as specified by rule 8.1115(b). This opinion has not been certified for publication or or dered published for purposes of rule 8.1115.

COURT OF APPEAL, FOURTH APPELLATE DISTRICT

DIVISION ONE

STATE OF CALIFORNIA

NEAL ELECTRIC CORPORATION,
Plaintiff and Appellant,

v.

CLARK CONSTRUCTION GROUP

- CA, L.P.,

Defendant and Respondent. D08 2217

(Super. Ct. No. PSC1805941)

APPEAL from a judgment of the Superior Court of County of Riverside,
Ronald L. Johnson (Retired judge of the San Diego Super. Ct. assigned by the Chief Justice pursuant to art. VI, § 6 of the Cal. Const.) and Randolph Rogers , Judge s . Affirmed. Procopio, Cory, Hargreaves & Savitch , Kendra J. Hall and Jeff S. Hood for Plaintiff and Appellant. Pillsbury Winthrop Shaw Pittman , Elaine Y. Lee, John R. Heisse , Daniel H. Bromberg , and Deborah B. Baum for Defendant and Respondent. Neal Electric Corporation, a subcontractor , appeals from a judgment enforcing an arbitration award in its dispute with general contractor Clark Construction Group

. Neal petitioned the court to vacate the award on the2

ground that it exceeded its authority by holding a virtual hearing , unfairly refused to postpone the hearing , and failed to issue a complete and final
award

. On appeal , Neal again argues that the arbitration panel exceeded its authority in ho lding a virtual hearing and in refusing to issue a complete and final award. We are unpersuaded by Neal’s claims of error and affirm the judgment. FACTUAL AND PROCEDURAL BACKGROUND A. Background Information
1. Neal and Clark’s Subcontract Agreement This dispute arises out of the construction of the East County Detention Center (Project) located in Indio, C alifornia

. Clark contracted with the Project owner , County of Riverside (County) , to serve as the general contractor for the Project. In May 2015 , Clark entered into a Subcontract Agreement (Subcontract) with Neal to perform electrical work on the Project

. The Subcontract includes several provisions concerning the settlement of disputes, including an arbitration clause. For any disputes not sett led pursuant to the Subcontract’s procedures, the Subcontract provide s : To the extent not resolved under Article 11.b above, any dispute between Clark and S ubcontractor shall, at Clark’s sole option, be decided by arbitration in accordance with the Const ruction Industry Arbitration Rules of the American Arbitration Association. If Clark elects to arbitrate, then the arbitration shall be in Riverside, CA.
From the start of the Project, Clark and its subcontractors encountered numerous problems with the plans provided by the Project’s architect, HOK Group, Inc

. (HOK). As a result, Clark and its subcontractors submitted thousands of inquiries , which severely delayed their work and increased their

costs.3

2

. Termination of Subcontract In 2018, Clark dem anded that Neal increase its workforce to complete the existing work

. When Neal refused to do so, Clark terminated the Subcontract. Neal sued Clark for wrongful termination and Clark successfully petitioned the court to compel arbitration per the terms of the
Subcontract. In November 2018, Clark filed an arbitration demand with the American Arbitration Association to recover the cost of completing and correcting Neal’s work

. In response, Neal reasserted its breach of contract claim against Clark.
B. Arbitration Proceeding
1. Scheduling Orders In August 2019, the arbit ration panel chair issued a scheduling order , which required the parties to file detailed statements of claims and defenses.
The order further stated that, after service of these statements, “no party may further amend its claims or defenses (other than c hanges in monetary amounts allowed by Rule R

- 6) without leave of the Arbitrator.” It set the evidentiary hearing schedule “at a location to be determined” and further provided that “[t]estimony will be presented in person absent extraordinary
circumstance s.” In December 2019, the panel chair issued a second scheduling order noting that the parties had served their detailed statements of claims and defenses. The order stated that no amendments beyond those dealing with monetary amounts would be allowed without leave of the panel c hair. It confirmed the evidentiary hearing dates and protocol and reiterated that “[t]estimony will be presented in person absent extraordinary circumstances.” It also set an August 2020 deadline for counsel to meet and confer and notify the panel of the proposed location for the evidentiary hearing.4

2. Virtual Hearing In light of the COVID

- 19 pandemic, which began in early 2020, the panel advised the parties that they would be required to follow a detailed protocol if the hearings were to proceed in person . During a telephonic status conference in August 2020, the panel advised the parties that “it was now likely to require that the hearings be conducted virtually

— i.e., by videoconference

— in light of the continuing risks p osed by the pandemic.” Neal prepared a written objection to proceeding virtually and requested a six

month continuance. Neal’s objection stated: The Subcontract provides that the arbitration shall be conducted in Riverside, California and the parties have not agreed to change the location of the hearing. The Subcontract does not contemplate, nor does Neal agree to, an entirely virtual arbitration proceeding.

Neal argued that an in

- person hearing was “imperative” due to “the scope and complexity of the dispute and amount of evidence that will be presented.” Neal asserted that “[a] virtual proceeding introduces a host of issues that will substantially impact the proceeding and result in prejudice,” including “inter net connectivity issues,” distractions, and difficulties presenting exhibits and examining witnesses. It also argued that a continuance was needed because “critical authorized discovery remains pending,” as two

- third s of the parties had not produced subpoenaed documents, and Neal was facing objections from third parties regarding three deposition subpoenas.
Neal acknowledged that it was “not possible to secure a facility that can guarantee accommodations that would meet the needs of the hearing due to governmental restrictions currently being imposed as a result of the COVID

-5

19 pandemic.” Neal’s objection stated that it would consider a virtual hearing
if a continuance was granted : If, after a reasonable continuan ce and after obtaining the necessary discovery at issue, it remains infeasible to proceed in

person, Neal will re

- evaluate proceeding virtually. Neal simply wants a reasonable opportunity to proceed in person as contemplated by the parties. Neal proposes the scheduling of a new hearing date be deferred to January 2021 and, based upon the level of restriction at such time, and status of the discovery disputes, a reasonable hearing date can be scheduled.
Clark opposed Neal’s request , arguing that the pan el ha d authority to order a virtual hearing

. Clark also argued that any prejudice caused by a virtual hearing would be borne equally by both parties. Clark also acknowledged that “no one expected that we would be in the middle of a pandemic, and that eve ryone would prefer an in

- person hearing where witnesses could testify at a normal distance, without masks, and all attendees could come and go as they please.”
The p anel denied Neal’s request for a continuance. The panel reasoned that “the risks created by an in

- person hearing, especially one such as this matter involving three [p] anelists, a large number of counsel, witnesses and experts, as well as a court reporter and possible technical support staff to assist in the presentati on of exhibits, outweigh any potential prejudice to the parties, which in any event is imposed equally on both sides .” (Fn. omitted

. ) The panel’s ruling on the request for a continuance stated the American Arbitrators Association and the National Academy of Arbitrators had concluded that, “in exceptional circumstances such as the current pandemic, arbitrators have the authority to order that a matter proceed by way of video hearing over the objection of a party to the arbitration.” The panel also ruled

t hat any prejudice to Neal’s ability to complete its third

- party discovery was6

outweighed by the prejudice to both parties of a lengthy continuance, particularly as Neal had failed to pursue third party discovery in a timely
manner. The panel also agreed t o make additional hearing days available if
needed to evaluate third party documents obtained during the hearings.
3. Hearing and Arbitration Award The hearing commenced in late November 2020 and was conducted virtually using the Zoom platform. Twenty witnesses testified over 20 days
and more than 680 exhibits were introduced into evidence. The panel chair commended the parties for “hav[ing] done a yoeman’s job in presenting what is a difficult and complex case.” Following the issu ance of an interim award, the panel issued a 77

- page award in August 2021 granting Clark a net recovery of approximately $9.67
million. The panel determined that Clark was justified in terminating Neal.
It concluded , “Neal defaulted when it refused Clark’s demands to increase its manpower when there was work available for it to perform, and in fact unreasonably reduced manpower.” It therefore hel d Clark properly terminated Neal and was entitled to damages.
The p anel considered Neal’s claims to damages arising from design deficiencies and discrepancies

. 1 The panel noted that Clark’s accounting included a credit to Neal of $1.07 million as its s hare of the money the County paid Clark in its settlement of these claims . The panel also noted

1 These claims to damages were initially addressed in $41 million worth of claims brought by Clark against the County, including $2.75 million for Neal’s losses. Clark and the County ultimately settled these claims f or $20 million. As part of that settlement, the County agreed to sue HOK using Clark’s financial and substantive assistance. At the time of the hearing, the County’s lawsuit against HOK was pending and Clark was to receive 75% of any proceeds from that suit ( after payment of attorneys’ fees )

.7

that Clark acknowledged that Neal was entitled to a share of any additional amounts recovered in the County’s suit against HOK. As a result, Neal was “entitle d to a credit in an unknown amount against the amount awarded in this matter, or payment by Clark if the award has been satisfied, if Clark receives proceeds from the lawsuit against HOK arising out of damages suffered by Clark’s subcontractors, including Neal.”
The pane l , however, was unable to calculate Neal’s potential recovery from the County ’s l itigation against HOK because “the amount of any future recovery by Clark is unknown, and the specific claims asserted in the lawsuit against HOK were not exp lored during the hearing of this matter.” The panel declined “to hold this proceeding in abeyance or retain jurisdiction” in the event of any future dispute over distribution of the proceeds of the County’s lawsuit against HOK

. It noted that the parties were free to file a

new arbitration demand if such a dispute arises and could “ reappoint the members of the [ p ] anel to hear that matter

. ” C

. Trial Court Proceeding Neal petitioned the trial court to vacate the a ward on the grounds that
the p anel exceeded its authority by holding the hearing virtually and failing to fully resolve the dispute, and unfairly refusing to postpone the hearing.
The court denied the petition. The court ruled that the panel did not exc eed its authori ty by conducting a virtual evidentiary hearing. The court observed that, w hen the parties agreed to the arbitration provision in the Subcontract, “the impact of the pandemic on holding in

- person proceedings was not on the horizon.” In
addi tion, the Subcontract did not require in

- person hearing s simply because
it states the arbitration “shall be in Riverside, CA.”8

The court also ruled that the panel did not fail to issue a final award by declining to issue Neal a credit for the pending lit igation between Clark and HOK . To the contrary, the c ourt observed, all the “issues framed by [Neal’s] Complaint” were “fully resolved by the [p] anel in its final award

. ” The fact
that Neal may be entitled to funds ultimately received by Clark from the litigation between Clark and HOK “does not change the fact that all of the issues in this case have been resolved.”
The court also ruled that Neal was not substantially prejudiced by the

p anel’s refusal to postpone the evidentiary hearing. The c ourt found the

p anel’s denial of the continuance was reasonable, that they would have
needed a virtual hearing even if it had been continued to January 2021, and that both parties equally felt any prejudi ce from a virtual hearing. DISCUSSION On appeal, a s it did in the proceedings before the trial court, Neal contends that the arbitration panel’s award should be set aside because the panel exceeded its authority by (1) holding the hearing virtually and (2) failing to issue a complete and final award

. 2 We consider these contentions after setting forth general principles guiding our de novo review. ( Advanced Micro Devices , Inc. v. Intel Corp. (1994) 9 Cal.4th 362, 376, fn. 9 ( Advanced Micro Devices ) .) A. Relevant Legal Principles Through the California Arbitration Act (§ 1280 et seq.), the Legislature has expressed a “ ‘strong public policy in favor of arbitration as a speedy and relatively inexpensive means of dispute resolution.’ ” ( Monch arsh v. Heily &

2 Neal did not appeal the court’s ruling that it was not substantially prejudiced by the panel’s refusal to postpone the evidentiary hearing.9

Blase (1992) 3 Cal.4th 1, 9

. ) “To promote this alternative means of dispute resolution, the law minimizes judicial intervention in the proceedings, in part, by the doctrine of arbitral finality.” ( Jones v. Humanscale Corp . (2005) 130 Cal. App.4th 401, 407.) As our Supreme Court has admonished, “arbitration judgments are subject to extremely narrow judicial review” ( Marsch v. Williams (1994)
23 Cal.App.4th 238, 243), and while acting in excess of authority is a recognized ground for vacating an arbitration award (Code Civ. Proc. , § 1286.2 , subd. (a)(4)), this ground is “narrowly construed.” ( Emerald Aero, LLC v. Kaplan (2017) 9 Cal.App.5th 1125, 1138. ) Parties to an arbitration

agre ement “have bargained for the relatively free exercise” of the arbitrator’s “flexibility, creativity and sense of fairness” in choosing a remedy. ( Advanced
Micro Devices , supra , 9 Cal.4th at p. 374.)
B. Panel’s Authority to Order Virtual Hearing Neal contends that the panel exceeded its authority by ordering a virtual evidentiary hearing. We disagree. To successfully dispute the panel’s interpretation of its authority under
the Subcontract’s arbitration provisio n, Neal faces a high bar

. Indeed, the panel’s award will not be overturned “as long as the [panel] is even arguably

. . . acting within the scope of [its] authority.” ( Advanced Micro Devices , supra , 9 Cal.4th at p. 37 8 .) Here, we conclude that the panel was acting within the scope of it s authority when it decided to proceed with a virtual evidentiary hearing. ( Gueyffier v. Ann Summers , Ltd . (2008) 43 Cal.4th 1179,
1182 ( Gueyffier ) [“Absent an express and unambiguous limitation in the

contract .

. . , an arbitrator has the authority to .

. . interpret the contract, and award any relief rationally related to his .

. . contractual interpretation.”].)10

According to Neal, the Subcontract required the panel to hold an in

person proceeding in Riverside. But there is no “express a nd unambiguous
limitation in the [ Subcontract ]” ( Gueyffier , supra , 43 Cal.4th at p. 1182 ) that
limits how arbitration proceedings are to be conducted , including whether they are to be held in

- person or online

. On the contrary, the Subcontract merely provi des that “the arbitration shall be in Riverside, CA.” The only guidance regarding whether the hearing was to take place in

- person or virtually , is provided by the construction industry rules of the American
Arbitration Association , which are explicitly incorporated into the Subcontract

. The Subcontract states : “ [A] ny dispute between Clark and Subcontractor shall, at Clark’s sole option, be decided by arbitration in accordance with the Construction Industry Arbitration Rules of the American
A rbitration Association.”11

The c onstruction i ndustry a rbitration r ules specifically allow for the virtual presentation of evidence. 3 Those rules give arbitrators “discretion .

. . [to] conduct the proceedings with a view toward expediting the resolution of the dispute.” (Rule R

- 33(b), Construction Industry AAA rules.) “When deemed appropriate,” the rules specifically provide that arbitrators may conduct proceedings that “ allow for the presentation of evidence by alternative means including video confer encing, internet communication, telephonic conferences and means other than an in

- person presentation.” ( Id. , Rule R

- 33(c).) The only limitation imposed on such proceedings is that they “ must still afford a full opportunity for all parties to present any
evidence that the arbitrator deems material and relevant to the resolution of the dispute and when involving witnesses, provide an opportunity for cross

3 As noted, the Subcontract expressly incorporates the American Arbitration Association ’s construction industry arbitration rules. The full, up
- to

- date text of those rules is available on the American Arbitration Association’s website at <https://www.adr.or g/construction > [ as of October 17, 2023 ], archived at <https://perma.cc/ G5HL

- NVZS >. Having given the parties appropriate notice before oral argument that we proposed to take judicial notice of the rules on our own motion (Evid. Code, § 459, subds. (c) & ( d)), we
now do take judicial notice of the Construction Industry Arbitration Rules of the American Arbitration Association (hereinafter Construction Industry AAA rules) , amended and effective July 1, 2015. (See Evid. Code, § 452, subd. (h) [permitting judicial notice of “[f]acts and propositions that are not reasonably subject to dispute and are capable of immediate and accurate determination by resort to sources of reasonably indisputable accuracy”] ; Boghos v. Certain Underwriters at Lloyd' s of London (2005) 36 Cal.4th 495, 505, fn. 6 ( Boghos ) [noticing A merican Arbitration Associatio n’ s commercial arbitration rules] ; Cooper v. Lavely & Singer Professional Corp. (2014) 230 Cal.App.4th 1, 6, fn. 1 ( Cooper ) [noticing rules of Judicial Arbitration and Mediation Services, Inc ] .)12

examination. ” ( Ibid. ) There is no contention here that the panel failed to provide a full opportunit y to present evidence or cross

- examine witnesses.
Neal contends that the arbitration provision “cannot be interpreted as permitting a virtual proceeding with the parties not in the same physical location as identified in the agreement.” It asserts that the specification that “the arbitration shall be in Riverside” is “res trictive” and implicitly eliminated the panel’s authority to conduct virtual hearings

. Contrary to Neal’s argument , we conclude it was not un reasonable for the panel to interpret the provision , in conjunction with the adopted construction industry
arbitra tion rules , as authorizing a virtual proceeding, particularly when faced
with an ongoing pandemic that made it “impossible” to hold an in

- person hearing in Riverside

. The panel explained that Neal “was unable to locate

any venue in Riverside County that c ould accommodate the number of people likely to attend the hearings and still comply with Riverside County’s
restrictions and the [p]anel’s protocol.” The panel determined that it was “impossible to hold an in

- person hearing” as scheduled , and that “a

con tinuance of the currently

- scheduled hearings would push the start of the hearings out nearly one year.”
Neal acknowledges that construction industry arbitration rules allow “the presentation of certain evidence . . . by alternate means,” but argues that
those rules do not provide the panel “authority for an entire proceeding to be presented virtually.” Although Neal makes a sensible distinction , the panel rationally determined that the pandemic made it “impossible to hold an in

person hearing” and that “conducting the hearing via videoconference is a
reasonable alternative to an in

- person hearing in light of the Covid

- 19 pandemic, stay

- at

- home orders, and travel limitations.” Neal even acknowledges that “an accommodation [for virtual testimony] may be m ade13

for certain witnesses.” Under the extraordinary situation of the pandemic
where in

- person meeting s were prohibited , the panel reasonably concluded
that all witnesses , as well as other participants, needed an accommodation to appear virtually

. Both parties and the panel cite to a National Academy of Arbitrators advisory opinion issued during the pandemic stating that an arbitrator “may order that a matter proceed by way of video hearing in whole or in part
without mutual consent and over the objection of a party.” 4 In support of its decision to conduct a virtual hearing in the face of the pandemic, the panel pointed to the advisory opinion ’ s statement that “ ‘ [g]overnment travel restrictions and family health considerati ons of counsel or witnesses may [ ] weigh in the arbitrator’s decision to order or not order a video hearing. ’ ”
Neal correct ly contends that the advisory opinion “ is not law and cannot displace the specific limitations contained in the parties’ arbitrati on agreement” or other rules and laws governing the arbitration

. Nevertheless, the panel was not incorrect or irrational to use it as guidance. ( Advanced
Micro Devices , supra , 9 Cal.4th at p p . 37 4

– 375 [ arbitrators “are not bound to
award on principles of dry law, but may decide on principles of equity and good conscience” ] .) Moreover, the distinction between the conduct of an arbitration and the location of an arbitration further supports the panel’s reasonable

4 The advisory opinion is available on the National Academy of Arbitrators website at < https://naarb.org/advisory

- opinions/ > [ as of October 17, 2023 ], archived at https://perma.cc/ 4BC7

- XDJK >

. Having given the pa rties appropriate notice before oral argument that we proposed to take judicial notice of it (Evid. Code, § 459, subds. (c) & (d)), we now do so. (See Evid. Code, § 452, subd. (h ) ; Boghos
, supra , 36 Cal.4th at p. 505, fn. 6; Cooper
, supra , 230 Cal.App.4th at p. 6, fn. 1

. )14

interpretation of its authorit y

. As discussed above, the construction industry
arbitration rules set out the “Conduct of Proceedings ,” which allows evidence to be presented by video conference

. (Rule R

- 33(c) , Construction Industry AAA rules .) The rules address the arbitration locati on in a separate section, “Fixing of Locale , ” which provides that the parties may determine the locale of the arbitration and sets forth how to resolve disputes concerning the locale. ( Id ., Rule R

- 12 .) The California Arbitration Act provides that the loc ation of
the arbitration determines its judicial seat

. (See Code Civ. Proc. , § 1292 , subd. (b) [a petition to enforce an agreement to arbitrate may be filed in “a county where the agreement is to be performed”] .) Consistent with this distinction, it was reasonable for the panel to find that the Subcontract’s identification of an arbitration locati on did not impliedly eliminate its authority to conduct virtual evidentiary hearings , a s set out explicitly in the construction industry arbitration rules

. I ndeed, if the parties sought to require the arbitrator to hold all proceedings in

- person, they wou ld have made that a material term of the
Subcontract

. They did not, and instead the agreement explicitly adopts the construction industry arbitration rules, which allow evidence to be presented virtually

. Because the parties did not “explicitly and unamb iguously limit[ ] [the panel ’s] powers” ( Gueyffier
, supra , 43 Cal.4th at p. 1185 ) to conduct hearings virtually , we are unable to say that the court erred in confirming
the award and rejecting Neal’s interpretation of the Subcontract

. ( Morris v.
Zuckerman (196 8 ) 69 Cal.2d 686, 690 [ “[A]ny doubts as to the meaning or extent of an arbitration agreement are for the arbitrators and not the court to resolve.” ] .) Accordingly, we must “refrain from substituting ” our own judgment or Neal’s judgment “ for the arbitrator’s in determining the contractual scope of [its] powers.” ( Advanced Micro Devices , supra , 9 Cal.4th15

at p. 372. ) Requiring the parties to proceed virtually did not “constitute misconduct [n]or [was it] so profound as to render the process unfair.” ( Heimlich v. Shivji (2019) 7 Cal.5th 350, 368.) C. Complete and Final Award Neal also argues the panel exceeded its au thority by failing to issue a complete and final award. Specifically, Neal contends that the panel should have resolved its entitlement to offsets arising from the County’s lawsuit against HOK. Instead of resolving the issue , according to Neal, the panel left
it “open” to be decided in “future, protracted litigation.” We disagree that the panel failed to resolve an issue or exceeded its authority

. Code of Civil Procedure s ection 1283.4 provides that the award “shall include a determination of all the q uestions submitted to the arbitrators the decision of which is necessary in order to determine the controversy.” “[I]t is for the arbitrators to determine what issues are ‘necessary’ to the ultimate decision.” (

Advanced Micro Devices , supra , 9 Cal.4th at p. 372.) The panel resolved the issue regarding potential offsets to Neal when it
determined that Clark owe d a credit to Neal if it recover ed additional amounts from the County’s litigation against HOK. Specifically, the panel ruled, “ Neal will be entitled to a credit in an unknown amount against the amount awarded in this matter, or payment by Clark if the award has been satisfied, if Clark r eceives proceeds from the lawsuit against HOK arising out of damages suffered by Clark’s subcontractors, including Neal.” Because the County’s lawsuit against HOK was still pending at the time of the hearing, it
was unclear how much the credit would be. The panel therefore reasonably
concluded that it was unable to determine the amount to which Neal was entitled from the pending litigation. To determine Neal’s share of a potential

recovery , the p anel would have needed to determine HOK’s liability to the16

County, the resulting damages the County would be awarded, and then figure out Clark’s net recovery , minus costs , before it could award Neal a share of that recovery. These issues were never presented to the panel. As the panel stated, “the specific clai ms asserted in the lawsuit against HOK were not explored during the hearing of this matter

. . . . ” In its reply brief, Neal suggests that it was “unnecessary for the panel to provide Neal a liquidated sum,” and that the panel instead “could have adopted a formula for future recovery, awarded a sum certain, stayed the matter, or reserved jurisdiction to issue a subsequent award.” But Neal does not explain what it means by a “liquidated sum” versus a “sum certain , ” or how the panel could have reliably cal culated either of those or a “formula for future recovery .” Moreover , where the County’s litigation against HOK could potentially have last ed several years, it was well within the panel’s discretion to “decline[ ] to hold this proceeding in abeyance or retain jurisdiction.” Having considered the various remedies , the panel gave the parties the option “to reappoint the members of the [p]anel” if any “future disputes aris[e] out of the distribution of any proceeds of the lawsuit against HOK.”
The panel acted within its authority where its “ discretion to determine the extent of remedies is as great as [its] discretion to determine the related question of what issues are necessary to the decision .” ( Advanced Micro
D evices , supra , 9 Cal.4th at p p. 372 , 374

– 37 5 [“ Were courts to reevaluate independently the merits of a particular remedy, the parties ’ contractual expectation of a decision according to the arbitrators ’ best judgment would be defeated. ”].) Finally, Neal r elies on cases that do not support reversal of the court’s judgment

. (See Ulene v. Murray Millman of California, Inc . (1959)
175 Cal.App.2d 655, 66 2 [affirming the court’s denial of motion to vacate an17

arbitration award after holding “ [ t ] here is no merit” to appellant’s contentions “that the alternative which the award gave [appellant] was vague
and indefinite , [and] that it did not finally decide the issue before the arbitrator” ]; Safeway Stores, Inc. v. Brotherhood of Teamsters (1978)
83 Cal.App.3d 430, 43 9 [ reversing the court’s decision vacating an arbitration
award and holding that “ mere ambiguity in the opinion accompanying an award, which permits the inference that the arbitrator may have exceeded his authority, is not a reason for refusing to enforce the award ” ] ; Rodrigues v.
Keller (1980) 113 Cal.App.3d 838, 842 ( Rodrigues ) [affirm ing court’s dismissal of action to set aside arbitrat ion award where “ the record does not demonstrate that any issue was submitted to the arbitrator which he totally failed to consider ” ] .)
In Banks v. Milwaukee Ins. Co

. (1966) 247 Cal.App.2d 34 , 39 the
arbitrator submitted a declaration to the court admitting “ ‘ through inadvertence, mistake and/or excusible [sic] neglect ’ ” he had “ ‘ omitted an award for general damages. ’ ” Based on the arbitrator’s declaration, the Court of Appeal determined that “ the issue of general damages had been submitted to the arbitrator, and that he had totally failed to consider it .” ( Id.

at p. 38.) Here, by contrast, the pan el did not fail to consider the issue, but
evaluated it and determined the amount of any future recovery from the pending litigation was “unknown

. ” Similarly, in M.B. Zaninovich, Inc. v.
Teamster Farmworker Local Union 946 (1978) 86 Cal.App.3d 410, 415 the
arbitration award was vacated where it was “fatally uncertain” because it failed to state the amount of the award. There, in contrast to here, the Court of Appeal determined the arbitrator could calculate the amount of the award
bu t failed to do so. ( Id. at p. 4 13 & fn. 1 [noting that “amount of the dues cannot be established without additional information which is not present in18

the award” and that “the information is in the possession of the [appellant] ” but that “does not cure a n uncertainty in the award o r in a judgment, as the law does not require a party to make a computation in order to render the judgment certain” ].) Here, by contrast, the panel determined it was unable to
calculate a potential award based on the uncertain outcome of pending litigation.
Because the outcome of the pending litigation was unknown , the panel reasonably refused to attempt to calculate the amount of a potential credit for
Neal

. ( See Morris v. Zuckerman (1968) 69 Cal.2d 686, 690 [ “It is for the arbitrators to determine which issues were actually ‘necessary’ to the ultimate decision.” ]; East San Bernardino County Water Dist. v. City of San
Bernardino (1973) 33 Cal.App.3d 942, 954 [ “The arbitrators, not th e courts, have the task of defining the issues between the parties.” ] .) Because Neal failed to meet its “burden of proving” that “all issues submitted for decision have [not] been passed on and resolved” ( Rodrigues , supra, 113 Cal.App.3d at

p. 842), the t rial court was correct to confirm the award.19 DISPOSITION The judgment is affirmed. 5 Clark shall recover its costs on appeal.

CASTILLO, J. WE CONCUR:

BUCHANAN, Acting P. J.

RUBIN, J.

5 Clark asks us to take judicial notice of two documents entered in the lawsuit between the County and HOK. We deny th e request as those items are not necessary to the resolution of this appeal. (See Mangini v. R.J. Reynolds Tobacco Co. (1994) 7 Cal.4th 1057, 1063; County of San Diego v. State of California (2008) 164 Cal.App.4th 580, 613, fn. 29.)