EX-4.b.6



 Exhibit 4.b.6 

CONFIDENTIAL TREATMENT REQUESTED UNDER RULE 24b-2 UNDER THE SECURITIES EXCHANGE ACT OF 1934, AS AMENDED. 

[***] INDICATES OMITTED MATERIAL THAT IS THE SUBJECT OF A CONFIDENTIAL TREATMENT REQUEST FILED SEPARATELY WITH THE COMMISSION. THE OMITTED MATERIAL HAS
BEEN FILED SEPARATELY WITH THE COMMISSION. 
 Software and Professional Services Agreement 

Master Services Agreement 
 No.
53258.C 
 Between 
 Amdocs,
Inc. 
 And 
 AT&T Services,
Inc. 
 Proprietary and Confidential 

This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and third party
representatives, and Supplier except under written agreement by the contracting parties. 

  
 1 









 Software and Professional Services Agreement 

 


	1.0	Preamble 

  

	1.1	Preamble 

 This Agreement is between Amdocs, Inc., a Delaware corporation (hereinafter
referred to as “Supplier”), and AT&T Services, Inc., a Delaware corporation (hereinafter referred to as “AT&T”), each of which may be referred to in the singular as a “Party” or in the plural as the
“Parties.” 
  

	1.2	Scope of Agreement: 

 Supplier shall provide to AT&T the Material and Services,
subject to the terms and conditions of this Agreement and pursuant to and in conformance with Orders submitted by Supplier or AT&T. Such Orders, once fully executed by the Parties, shall be deemed to incorporate the provisions of this Agreement
(including the Appendices and Exhibits attached hereto) as though fully set forth therein. 
  

	1.3	Term of Agreement 

  

	 	a.	After all Parties have signed, this Agreement shall be effective on the last date signed by a Party (“Effective Date”), and shall continue until September 30, 2021 (“Expiration Date”) unless
earlier terminated as set forth herein. The Parties may extend the Term of Agreement by executing an amendment to this Agreement. 

  

	 	b.	Any Order in effect on the date when this Agreement expires or is terminated will continue in effect until such Order either (i) expires by its own terms or (ii) is separately terminated, prior to its own
scheduled expiration, as provided in this Agreement. The terms and conditions of this Agreement shall continue to apply to such Order as if this Agreement were still in effect. 


 

	2.0	Definitions 

  

	2.1	Accept or Acceptance 

 “Accept” or “Acceptance” means
AT&T’s acceptance of the Material or Services ordered by AT&T and provided by Supplier as specified in the applicable Order. AT&T’s Acceptance shall occur no earlier than as specified in Section 3.9. 

 

	2.2	Acceptance Date 

 “Acceptance Date” means the date on which AT&T
Accepts Material or Services. 
  

	2.3	Acceptance Letter 

 “Acceptance Letter” means a document signed by
AT&T substantially in the form of Appendix F indicating its Acceptance of the Material and/or Services. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 2 









 Software and Professional Services Agreement 

 


	2.4	Acceptance Test Period or Trial Period 

 “Acceptance Test Period” or
“Trial Period” means the length of time specified in an Order, or, if not so specified, a period of no less than [***] days and no more than[***] days, during which the Acceptance Tests are performed. 

 

	2.5	Acceptance Tests 

 “Acceptance Tests” means the performance and
reliability demonstrations and tests that must be successfully completed by the Material and Services during the Trial Period. These tests include: (i) AT&T’s routine business test transactions, (ii) tests, demonstrations, or
transactions presented or performed by Supplier, and (iii) any other tests, demonstrations or transactions included or referenced in the applicable Order or Specifications, all to determine whether the Material or Services meet the
Specifications. 
  

	2.6	Affiliate 

 “Affiliate” means (i) with respect to AT&T, a
business association that has legal capacity to contract on its own behalf, to sue in its own name, and to be sued, if and only if either (a) such business association owns, directly or indirectly, a majority interest in AT&T (its
“parent company”), (b) a majority interest in such business association is owned, either directly or indirectly, by AT&T or its parent company, or (c) such business association is a certain rural local telephone company that is a
party to that certain Joint Operating Agreement dated as of September 28, 2000, pursuant to which AT&T Mobility LLC and such telephone company jointly conduct their respective wireless operations within MTA 006; and (ii) with respect
to Supplier, any business association that has legal capacity to contract on its own behalf, to sue in its own name, and to be sued, if and only if that business association controls, is controlled by, or is under common control with Supplier, where
“control” means the direct or indirect holding of 50% or more of the equity and/or voting rights. 
  

	2.7	Agreement 

 “Agreement” means the written agreement between the Parties
as set forth in this document and the attached appendices and shall include the terms of such other documents as are incorporated by express reference in this document and the attached appendices, as well as any Orders that may be issued pursuant to
this Agreement. 
  

	2.8	AT&T Data 

 “AT&T Data” means any data or information
(i) of AT&T or its customers, that is disclosed or provided to Supplier by, or otherwise obtained by Supplier from, AT&T or its customers, including Customer Information and customer proprietary network information (as that term is
defined in Section 222 of the Communications Act of 1934, as amended, 47 U.S.C. §222), as well as data and information with respect to the businesses, customers, operations, networks, systems, facilities, products, rates, regulatory
compliance, competitors, consumer markets, assets, expenditures, mergers, acquisitions, divestitures, billings, collections, revenues and 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 3 









 Software and Professional Services Agreement 

 

 
finances of AT&T; and (ii) not supplied by AT&T or its customers, but created, generated, collected or harvested by Supplier either (a) in furtherance of this Agreement or an
Order hereunder or (b) as a result of Supplier having access to AT&T infrastructure, systems, data, hardware, software or processes (for example, through data processing input and output, service level measurements, or ascertainment of
network and system information). Notwithstanding the foregoing, the Parties agree that “AT&T Data” shall not be deemed to include material or software (I) created or owned by Amdocs prior to execution of this Agreement,
(II) provided under license from third parties by Amdocs prior to execution of this Agreement, (III) created by Amdocs or third parties after execution of this Agreement for a client other than AT&T or (IV) that Supplier owns in
accordance with this Agreement or as agreed by the Parties in an Order. 
  

	2.9	AT&T Derived Data or AT&T Derived Information 

 “AT&T Derived
Data” or “AT&T Derived Information” means any data or information that is a result of or modification of, adaption, revision, translation, abridgement, condensation, compilation, evaluation, expansion, or any other
recasting or processing of the AT&T Data, for example, as a result of Supplier’s observation, analysis, or visualization of AT&T Data arising out of the performance of Supplier’s obligations. Notwithstanding the foregoing, the
Parties agree that “AT&T Derived Data” shall not be deemed to include Supplier’s material or software that does not constitute AT&T Data as set forth in Subsection I of Section 2.8, “AT&T Data,” above and
[***]. 
  

	2.10	Call Center Work 

 “Call Center Work” means work centralized in a
physical place where telephone calls are handled by Supplier, usually with some amount of computer automation, as agreed by the Parties in an Order. 
  

	2.11	Critical Performance Milestone 

 “Critical Performance Milestone” means
a date certain or the end of a stipulated interval of time for the Delivery of an item of Program Material or Software or the completion of performance of a Service, the timely completion or delivery of which is considered to be critical to the
success for the Project and which is expressly referred to in an Order as a “Critical Performance Milestone”. 
  

	2.12	Custom Software 

 “Custom Software” means any and all Software to the
extent it constitutes Paid-For Development. 
  

	2.13	Customer Information 

 “Customer Information” includes, but is not
limited to, customer name, address, and phone number, any customer or employee personal information, credit card and credit-related information, health or financial information, authentication credentials, information concerning a customer’s
calling patterns, unlisted customer numbers, any other information associated with a 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 4 









 Software and Professional Services Agreement 

 

 
customer or with persons in the household of a customer, and any information available to AT&T and/or its suppliers by virtue of AT&T’s relationship with its customers as a provider
of telecommunications, Internet, information or other services, including the quantity, technical configuration, location, type, destination, and amount of use of telecommunications or other services subscribed to, and information contained on the
telephone bills of AT&T’s customers pertaining to telephone exchange service, telephone toll service or other services received by a customer of AT&T. 
  

	2.14	Delivery 

 “Deliver” or “Delivery” means
Supplier’s obligation to provide Material and/or Servicesthat [***] conform to the Specifications. Delivery occurs: (i) with respect to tangible Material, upon AT&T’s possession of the Material, if Supplier is not required to
provide additional Services in connection with the Delivery, such as installation, (ii) with respect to Software upon AT&T’s receipt of electronic transmission or receipt by AT&T of the media upon which the Software resides, or
(iii) for Services or Material for which Services are to be provided, upon completing the provision of Services with respect to an applicable Milestone or scope of Delivery. 

 

	2.15	Delivery Date 

 “Delivery Date” means the date on which Supplier is
scheduled to complete its Delivery as established in an Order. 
  

	2.16	Documentation or Program Material 

 “Documentation” or “Program
Material” includes user instructions and system manuals, training Material in machine readable or printed form, Supplier’s written Specifications, Material associated with Software, flow charts, data file listings, and input and output
formats, provided by Supplier under the applicable Order. If the applicable Order so provides, Program Material will also include the source code for the Custom Software. 
  

	2.17	Equipment 

 “Equipment” means all tangible products and equipment used
to operate the Software and/or all tangible products and equipment provided by or on behalf of Supplier. 
  

	2.18	Error or Defect 

 “Error” or “Defect” shall mean
defects found in Custom Software which causes the Custom Software not to function in compliance with the Specifications. 
  

	2.19	Harmful Code 

 “Harmful Code” includes any and all instructions designed
to prevent a computer from producing intended results or to cause a computer to produce unintended results, including, but not limited to the following: instructions designed to halt or disrupt the operation of a computer


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 5 









 Software and Professional Services Agreement 

 

 
program at an arbitrary time (“time bombs”) or upon the execution of an arbitrarily designated instruction (“logic bombs”); instructions designed to cause the computer to
duplicate these instructions and retransmit those instructions to others, with or without additional disabling effects or instructions designed to cause the computer to maliciously erase its own data files (“viruses/worms”); instructions
designed to override security features and facilitate access to the computer by unauthorized users (“back doors,” “trap doors,” and “undocumented passwords”) or to place the operation of the computer under the control
of unauthorized remote users (“Trojan horses”). Harmful Code shall not include any key locks, or capacity limits on the operation of a computer program or software to the extent licensed by AT&T with those restrictions. 

 

	2.20	Incident 

 “Incident” shall be applicable only to Orders for Call Center
Work and means a suspected or actual attack upon, intrusion upon, unauthorized access to, loss of, or other security breach involving Information Resources. In such case Supplier is required to promptly [***] notify AT&T Asset Protection by
telephone at 800-807-4205 from within the US and at
1-908-658-0380 from elsewhere whenever there is a suspected or actual attack upon, intrusion upon, unauthorized access to, loss
of, or any other breach of In-Scope Information. This notification is in addition to and not in replacement of those notification requirements contained within the AT&T Supplier Information Security
Requirements (SISR). 
 Examples of Incidents to report to AT&T include but are not limited to the following: 

 

	 	•	 	Suspected improper or fraudulent use of customer or employee information 

  

	 	•	 	Theft or loss of sensitive customer or employee information 

  

	 	•	 	Accidental or intentional disclosure of sensitive customer information to a third party, such as: 

  

	 	•	 	Customer call records, billing information, or other CPNI 

  

	 	•	 	Customer financial account, banking or credit information 

  

	 	•	 	Customer Social Security Number or date of birth 

  

	 	•	 	Accidental or intentional disclosure of sensitive employee information to a third party , such as: 

  

	 	•	 	Employee Social Security Number, date of birth, or financial account information, 

  

	 	•	 	Employee medical information or health-related records 

  

	 	•	 	Employee human resources records 

  

	 	•	 	Improper storage, disposal, or retention of confidential AT&T customer or employee files or records 

  

	 	•	 	A security breach, as that term is commonly defined 

  

	 	•	 	Other customer or employee privacy-related issues or occurrences that may negatively impact employees or customers or result in negative financial and/or reputational consequences to AT&T 


 

	2.21	Information 

 “Information”, with respect to a Party, means all
confidential, proprietary or trade secret information, including discoveries, ideas, concepts, know-how, techniques, processes, procedures, designs, specifications, strategic information, proposals, requests
for proposals, 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 6 









 Software and Professional Services Agreement 

 

 
proposed products, drawings, blueprints, tracings, diagrams, models, samples, flow charts, data, computer programs, marketing plans, Customer Information (including Internet activities, history,
and/or patterns of use), employee personal information, health or financial information, authentication credentials, and other technical, financial or business information, whether disclosed in writing, orally, or visually, in tangible or intangible
form, including in electronic mail or by other electronic communication. 
  

	2.22	Intellectual Property Rights 

 “Intellectual Property Rights” means all
patents (including all reissues, divisions, continuations, and extensions thereof) and patent applications, trade names, trademarks, service marks, logos, trade dress, copyrights, trade secrets, mask works, rights in technology, know-how, rights in content (including performance and synchronization rights), or other intellectual property rights that are in each case protected under the Laws of any governmental authority having
jurisdiction. 
  

	2.23	Laws 

 “Laws” includes all statutes, ordinances, regulations, orders,
administrative rules and codes of any jurisdiction applicable to this Agreement. 
  

	2.24	License Order 

 “License Order” means an Order to license
Supplier’s or a Supplier Affiliate’s proprietary generic software product, solely in object code form that does not include any Material or Services which constitute Paid-For Development. 

 

	2.25	Material 

 “Material” means a unit of Equipment, apparatus, components,
tools, supplies, material, Documentation, Hardware, or firmware thereto, or Software purchased or licensed hereunder by AT&T from Supplier or otherwise provided by or on behalf of Supplier, including third party Material provided or furnished by
Supplier. “Material” shall be deemed to include any replacement parts. 
  

	2.26	OnGoing Support 

 “OnGoing Support” or “OnGoing Support
Services” (OGS) mean the Services as described herein and the applicable Order. 
  

	2.27	Order 

 “Order” means such paper or electronic records (a) as
AT&T may send to Supplier for the purpose of ordering Material and Services hereunder, or (b) as the Parties may execute for the purpose of ordering Material and Services hereunder. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 7 









 Software and Professional Services Agreement 

 


	2.28	Production Support 

 “Production Support” means support services for
Software and Systems in production which are not covered under an Amdocs warranty in an Order. For avoidance of doubt, Work performed by Amdocs in Production Support is itself subject to the OnGoing Support Services warranty provisions herein. 

 

	2.29	Project 

 “Project” means the development of Custom Software and/or
providing Services to AT&T. 
  

	2.30	Project Manager 

 “Project Manager” means each Party’s manager
responsible for a Project and identified on the applicable Order. 
  

	2.31	Revision 

 “Revision” means an update to the Documentation to reflect
the addition, deletion or correction of the previous version of the Documentation. A Revision may also be referred to as a documentation update. 
  

	2.32	Services 

 “Services” means any labor or service provided in connection
with this Agreement or any Order, including any Documentation or material provided in connection with the Services that is not otherwise Material as defined herein. 
  

	2.33	Software 

 “Software” means any and all software (including Custom
Software, Standard Software and firmware) in any form (including, for Custom Software, source code as applicable and object code), as well as any Documentation, licensed or otherwise provided by or on behalf of Supplier, excluding any Third Party
Software. 
  

	2.34	Specifications 

 “Specifications” means (i) Supplier’s
applicable specifications and descriptions, and (ii) any other requirements, specifications, and descriptions agreed by the parties and specified in, or attached to, an applicable Order. 

 

	2.35	Standard Software 

 “Standard Software” means Supplier’s or a
Supplier Affiliate’s proprietary generic software product, solely in object code form, that is licensed to AT&T in accordance with the Software Master Agreement No. 03032360 (as amended) or an applicable License Order. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 8 









 Software and Professional Services Agreement 

 


	2.36	Subcontractor 

 “Subcontractor” means any person or entity (including an
agent) supplying labor or materials to perform any or all of Supplier’s obligations under this Agreement, including any person or entity at any tier of subcontractors, and shall not be limited to those persons or entities with a direct
relationship with Supplier. 
  

	2.37	System 

 “System” means the operating environment for Software and
includes the Hardware on which the Software resides and the operating Software, application Software, databases which interact with such Software, and the Software and Hardware interfaces among such Hardware and Software. 

 

	2.38	Third-Party Software 

 “Third-Party Software” means any Software not
owned by Supplier or AT&T or their Affiliates. 
  

	2.39	Vulnerability 

 “Vulnerability” means a condition in the instructions of
the Software, whether consistent with its Specifications or not, that renders the computer on which the Software is operating susceptible to unauthorized access and use. 
  

	2.40	Work 

 “Work” means all or any portion, as the case may be, of the
Material and Services that Supplier is supplying pursuant to Orders placed under this Agreement. 
  

	3.0	General Terms 

  

	3.1	AT&T Affiliate 

  

	 	a.	 An AT&T Affiliate may transact business under this Agreement and place Orders with Supplier that incorporate
the terms and conditions of this Agreement. References to “AT&T” herein are deemed to refer to an AT&T Affiliate when an AT&T Affiliate places an Order with Supplier under this Agreement, or when AT&T places an Order on
behalf of an AT&T Affiliate, or when an AT&T Affiliate otherwise transacts business with Supplier under this Agreement. To the extent that the pricing under this Agreement or any Orders provides for discounts of any sort based on volume of
purchases by AT&T (including percentage discounts and tier-based pricing) or requires a certain volume of purchases by AT&T, [***]. An AT&T Affiliate is solely responsible for its own obligations, including all charges incurred in
connection with such an Order or transaction. Nothing in this Agreement is to [***], nor is anything in this Agreement to be construed to require any AT&T Affiliate to indemnify Supplier, or to otherwise assume any responsibility, for the acts
or omissions of 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 9 









 Software and Professional Services Agreement 

 


	 	
AT&T or any other AT&T Affiliate. To the extent that the Affiliate is not based in the United States or is purchasing Services to be provided outside the United States and a Party
reasonably believes that additional or different terms should be applied in the Order, the Parties shall negotiate in good faith on the additional or different terms to be included in the Order or a Supplement to this Agreement. 


 

	 	b.	Notwithstanding the foregoing, the Parties agree as follows: 

  

	 	i.	If a then-current AT&T Affiliate desires to place Orders with Supplier for Material or Services, and such AT&T Affiliate has an existing agreement with Supplier, AT&T shall determine under which agreement
the Order will be placed; and 

  

	 	ii.	To the extent AT&T acquires an entity or business with a pre-existing contractual relationship with Supplier, then AT&T shall determine whether the acquired entity or
business will process any new Orders under this Agreement or under the pre-existing contractual relationship. 

  

	3.2	Amendments and Waivers 

  

	 	a.	The Parties may not amend this Agreement or an Order except by a written agreement of the Parties that identifies itself as an amendment to this Agreement or such Order and is signed by both Parties, or as otherwise
expressly provided below in this Section. No waiver of any right or condition is effective unless given in writing and signed by the Party waiving such right or condition. No delay or omission by either Party to exercise any right or power it has
under this Agreement shall impair or be construed as a waiver of such right or power. A waiver by any Party of any breach, condition or covenant shall not be construed to be a waiver of any succeeding breach or condition or of any other covenant.
All waivers must be in writing and signed by the Party waiving its rights. 

  

	 	b.	AT&T’s Project Manager may, at any time, make changes to the scope of Work, which shall be confirmed in writing, and Supplier shall not unreasonably withhold or condition its consent. An equitable adjustment
shall be made to the charges if such change to the scope affects the time of performance or the cost of the Work, including expenses, to be performed under this Agreement. Such cost adjustment shall be made on the basis of the fees
specified in the Order for the Work, unless otherwise agreed in writing. 

  

	3.3	Anticorruption Laws 

 Supplier and its employees, temporary workers, agents, consultants,
partners, officers, directors, members or representatives of Supplier and its Subcontractors, if any, performing Services or other activities under this Agreement (each and any of the foregoing individuals, for the purpose of this Section, a
“Supplier Representative”) shall comply with the US Foreign Corrupt Practices Act and all applicable anticorruption laws (including commercial bribery laws). Supplier Representatives shall not directly or indirectly pay, offer, give,
promise to pay or authorize the payment of any portion of the compensation received in connection with this Agreement or any other monies or other things of value in connection with its performance to a Government


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 10 









 Software and Professional Services Agreement 

 

 
Official, as such term is defined below, to obtain or retain business or secure any improper advantage nor shall it permit such actions by a third party in connection with this Agreement. For
purposes of this Section, “Government Official” means: (i) an officer or employee of any government or any department, agency, or instrumentality thereof, including government-owned or government-controlled commercial entities;
(ii) an officer or employee of a public international organization; (iii) any person acting in an official capacity for or on behalf of any government or department, agency, or instrumentality or public international organization;
(iv) any political party or official thereof; (v) any candidate for political office; or (vi) any other person, individual or entity at the suggestion, request or direction or for the benefit of any of the above-described persons or
entities. 
  

	3.4	Assignment and Delegation 

  

	 	a.	Neither Party may, nor will it have the power to, assign, delegate, or otherwise transfer its rights or obligations under this Agreement, without the prior written consent of the other Party, except in the following
circumstances: 

 AT&T may assign its rights and obligations under this Agreement, without the approval of Supplier, to an
AT&T Affiliate and Supplier may assign its rights and obligations under this Agreement, without the approval of AT&T, to a Supplier Affiliate, which in either case has the necessary capability, standing, resources and solvency as reasonably
determined by the non-assigning Party to perform the Agreement and which expressly assumes such assigning Party’s obligations and responsibilities hereunder, and which is not a direct competitor of the
other Party; provided, however, that the assigning Party shall remain fully liable for and shall not be relieved from the full performance of all obligations under this Agreement without the consent of the other Party. A Party assigning its rights
or obligations in accordance with this Section shall, within[***] after such assignment, provide notice thereof to the other Party together with a copy of any relevant provisions of the assignment document. 

 

	 	b.	Each Party may assign its right to receive money due hereunder, but any assignment of money will be void to the extent (i) the assignor fails to give the non-assigning Party
at least thirty (30) days prior written notice, or (ii) the assignment purports to impose upon the non-assigning Party additional costs or obligations in addition to the payment of such money, or
(iii) the assignment purports to preclude AT&T from dealing solely and directly with Supplier in all matters pertaining to this Agreement. Any assignment, delegation or transfer for which consent is required hereby and which is made without
such consent given in writing will be void. 

  

	 	c.	Supplier may subcontract its performance subject to the Section herein entitled “Work Done by Others”. 

  

	3.5	Compliance with Laws 

  

	 	a.	Supplier shall comply with all Laws applicable to Supplier attendant upon Supplier’s performance under this Agreement. AT&T shall comply with all Laws applicable to AT&T attendant upon AT&T’s
performance of its obligations under this Agreement and AT&T’s or its customers’ utilization of the Material and/or Services. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 11 









 Software and Professional Services Agreement 

 


	 	b.	Supplier shall procure all approvals, bonds, certificates, insurance, inspections, licenses, and permits that such Laws require with respect to Supplier’s performance of this Agreement. Supplier shall create and
maintain any necessary records and provide any certificate, affidavit or other information or documentation requested or as otherwise required by AT&T: (a) to show compliance by Supplier and its Subcontractors with Laws; (b) necessary
for AT&T to comply or otherwise establish AT&T’s compliance with Laws; or (c) to allow AT&T to timely respond to any complaints, filings, or other proceedings. 


 

	 	c.	To the extent any modifications to Software or Services to be delivered to AT&T are required for the purposes of complying with Laws relating to AT&T’s business, Supplier will assist AT&T to comply with
such Laws as specified by AT&T by complying with the Specifications in the applicable Order. Upon request by AT&T, Supplier shall make available to AT&T appropriate product and subject matter experts as may reasonably be required in
assisting AT&T in defining the business requirements and functionality required for AT&T to comply with any and all Laws, all to the extent expressly agreed to in the Specifications in the applicable Order, provided, however, that in so
assisting AT&T, Supplier shall not be required to provide, and Supplier shall not be deemed to have provided, any legal services, advice or counsel to AT&T. All changes and/or modifications to be made to the Software or Services as requested
by AT&T due to changes in Laws as identified by AT&T will be handled in accordance with the change management procedures of this Agreement. 

  

	 	d.	Export/Import Law and Foreign Trade Controls  

  

	 	i.	Each Party shall comply with all export control, import and foreign trade sanctions laws, rules and regulations, in its performance of this Agreement. Without prejudice to the generality of the foregoing, Supplier
understands and acknowledges that certain AT&T applications and Materials and Services (including technical assistance and technical data) to be provided hereunder may be subject to export controls under the laws and regulations of the United
States, the European Union and other foreign trade control laws, rules and regulations restricting their transfer to certain countries and parties including but not limited to the US Export Administration Regulations and trade sanctions programs
administered by the US Department of the Treasury. Supplier shall comply with all applicable export control and other foreign trade laws, rules and regulations in performance of its obligations hereunder, and shall not use, resell, export, transfer,
distribute, dispose or otherwise deal with the AT&T applications or any technical data related thereto, directly or indirectly, except in full compliance with such laws, rules and regulations. 


 

	 	ii.	Neither Party shall use, sell, export, re-export, distribute, transfer, dispose or otherwise deal with any such Material or any direct product thereof nor undertake any
transaction or Service without first obtaining all necessary written consents, permits and authorizations and completing such formalities as may be required by any such laws or regulations. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 12 









 Software and Professional Services Agreement 

 


	 	iii.	Supplier shall be solely responsible for arranging export clearance, including applying for and obtaining any permits, licenses or other authorizations and complying with export clearance formalities, for all exports of
Materials and Services made by Supplier hereunder, including but not limited to exports by Supplier to its Affiliates or Subcontractors and exports from such Affiliates or Subcontractors to Supplier or to AT&T in the United States. AT&T
agrees to use reasonable efforts to obtain and provide to Supplier in a timely manner any end-user, end-use and other documentation and certifications as may reasonably
be requested by Supplier in support of any applications made to relevant government authorities in connection with such exports. 

  

	 	iv.	Supplier specifically represents and warrants that it shall not export/re-export or otherwise transfer the AT&T applications, Materials or Services to any country that is
subject to US trade sanctions imposed from time to time (currently, Cuba, Iran, North Korea, Sudan and Syria), to any persons or entities located in or organized under the laws of such country, or who are owned or controlled by or acting on behalf
of the governments of such countries, as well as to citizens of such countries, or to persons identified from time to time on applicable US government restricted party lists (the US Department of Commerce’s Denied Party List, Entity List,
Unverified List; the US Department of the Treasury’s List of Specially Designated Nationals and Other Blocked Persons; the US Department of State’s various non-proliferation lists).


  

	 	v.	Supplier represents and warrants that it has in place compliance mechanisms sufficient to assure compliance with applicable export control and foreign trade control laws, rules and regulations. Supplier shall not do
anything which would cause AT&T to be in breach of applicable export control or foreign trade control laws, rules and regulations, and shall protect, indemnify and hold harmless AT&T from any claim, damages, liability costs, fees and
expenses incurred by AT&T as a result of the failure of omission of Supplier to comply with such laws, rules and regulations. 

  

	 	vi.	Failure by Supplier to comply with applicable export control and foreign trade control laws, rules and regulations shall constitute a material breach of this Agreement. 


 

	 	e.	The provisions of this Section, “Compliance with Laws”, will survive the expiration or termination of this Agreement for any reason. 


 

	3.6	Construction and Interpretation 

  

	 	a.	This Agreement has been prepared jointly and has been the subject of arm’s length and careful negotiation. Each Party has been given the opportunity to independently review this Agreement with legal counsel and
other consultants, and each Party has the requisite experience and sophistication to understand, interpret and agree to the particular language of its provisions. Accordingly, the drafting of this Agreement is not to be attributed to either Party.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 13 









 Software and Professional Services Agreement 

 


	 	b.	Article, Section and paragraph headings contained in this Agreement are for reference purposes only and are not to affect the meaning or interpretation of this Agreement. The word “include” in every form means
to include without limitation by virtue of enumeration and a derivative of a defined term shall have the meaning appropriate to the context of its use. Whenever this Agreement refers to a consent or approval to be given by either Party, such consent
or approval is effective only if given in writing and signed by the Party giving approval or consent. The use of singular words includes the plural and vice versa. 


 

	3.7	Cumulative Remedies 

 Except as specifically identified as a Party’s sole remedy
including without limitation as set forth in the Section titled “Warranty”, any rights of termination, liquidated damages, or other remedies prescribed in this Agreement, the rights and remedies of the Parties set forth in this Agreement
are not exclusive of, but are cumulative to, any other rights or remedies set forth in the Agreement or the applicable Order, at law, or in equity. Neither Party may retain the benefit of inconsistent remedies. No single or partial exercise of any
right or remedy with respect to one breach of this Agreement or any Order precludes the simultaneous or subsequent exercise of any other right or remedy with respect to a different breach. 

 

	3.8	Special Software Terms 

  

	 	a.	Standard Software License and License Fees 

  

	 	i.	Any Standard Software licensed to AT&T will continue to be licensed in accordance with the terms of the applicable agreements, except as otherwise agreed by the Parties and specified in an Order. Any additional or
different Standard Software not previously licensed by Supplier shall be subject to separate agreements to be negotiated by the Parties, unless otherwise agreed to in an Order. 


 

	 	b.	Custom Software Development 

  

	 	i.	Supplier shall develop the Custom Software in compliance with the applicable Order. During the development process, AT&T shall assist Supplier and cooperate with Supplier by making employees available to Supplier
for consultation and providing information, facilities, equipment and data required for the performance of the Services. The Parties shall mutually develop a Project plan utilizing Project management methodologies agreed to by the Parties, and
predicated upon the Project’s requirements. The Project plan shall include deliverables, milestones and reviews. 

  

	 	ii.	In accordance with the Project plan and applicable Specifications, Supplier shall develop, complete, and deliver to AT&T all programming to be included in the Custom Software. All Custom Software developed by
Supplier shall be documented concurrently with its programming. In accordance with the Project plan, AT&T shall provide to Supplier the relevant test and interface data and test scripts. All Custom Software provided to AT&T hereunder shall
be tested (including unit subsystem and system testing) and debugged by Supplier, unless otherwise specified in the Order. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 14 









 Software and Professional Services Agreement 

 


	 	iii.	After the completion of such testing and debugging, Supplier shall Deliver (and install, if applicable) such Custom Software to AT&T on or before the scheduled Delivery Date set forth in the applicable Order.
Delivery shall be in accordance with Subsection c of Section 3.10 “Delivery of Software” below. The protocol for Acceptance Tests after Delivery is described below in Section 3.9 “Acceptance or Rejection.”


  

	 	iv.	Each Order will be subject to the governance procedures applicable to such Order. The respective Project Managers shall review each Party’s progress in meeting its objectives under the Project plan. Upon the
request of AT&T’s Project Manager or on Supplier’s initiative, Supplier’s Project Manager will provide a written progress report identifying any circumstance (including but not limited to any discovery of ambiguity in any
previously approved Specifications) coming to light since the previous such meeting which is likely to result in (i) a delay in Supplier’s ability to meet its due dates, or (ii) a proposed adjustment in projected amounts likely to be
billed to AT&T for time and charges, or (iii) both such a proposed adjustment and such a delay. The report will provide Supplier’s best estimate of the length of such projected delay and the amount of such proposed adjustment to time
and charges. To the extent that any such circumstance is shown to have resulted from a failure of AT&T (including any contractor or subcontractor of AT&T) to meet its obligations with respect to the Project, Supplier shall be granted an
equitable extension of time and an equitable adjustment of the fixed or estimated fee to the extent necessary to remedy AT&T’s failure to meet its obligations. Supplier waives any and all claims for any such equitable extension or
adjustment to the extent that it is based on any such circumstance in which Supplier failed to notify AT&T within one month (or otherwise specified in the Order) of Supplier’s recognition of the problem. 


 

	 	v.	Each equitable extension of time and each equitable adjustment of any fixed or estimated fee shall be recorded in an amendment to the Order, which shall be prepared by the respective Project Managers of each Party. In
addition, if AT&T desires to make a change in any previously approved Specifications, then AT&T shall deliver a change request to Supplier, and Supplier shall respond by providing a written change quote specifying any proposed adjustment to
time and charges that Supplier believes necessary to effectuate the change. If AT&T accepts the proposed change, the Parties shall amend the applicable Order. For clarity, each such change shall become an amendment to the applicable Order when
signed by the appropriate representative of each Party. If Program Material or Custom Software is not Delivered to AT&T (and installed, if applicable) as a result of factors under Supplier’s responsibility and control which includes
Supplier’s Subcontractors and agents on or before the scheduled Critical Performance Milestone Date or Delivery Date therefore (as extended by any amendment), AT&T may, at its option, and subject to resolution of any related dispute in
accordance with this Agreement’s dispute resolution process: 

  

	 	1.	[***] scheduled Critical Performance Milestone Date or Delivery [***]; or 

  

	 	2.	[***] the Order covering such Custom Software [***] Software, [***]; or 

  

	 	3.	[***] the Order covering such Custom [***] under the Order [***]; provided, however, that [***]; or 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 15 









 Software and Professional Services Agreement 

 


	 	4.	[***] as set forth in the applicable Order. 

  

	 	5.	[***] pursuant to this Section, each Party shall[***]. 

  

	 	vi.	From time to time AT&T may authorize Supplier to use computer systems that are physically located on AT&T’s premises. Such authorization shall be limited to Projects specified in writing by AT&T.


  

	 	vii.	Supplier shall notify AT&T as soon as reasonably possible of any Custom Software issues and risks that are identified by Supplier staff that may materially impact the Project and provide Custom Software development
progress reports as reasonably requested by AT&T. 

  

	3.9	Acceptance or Rejection 

  

	 	a.	After the Delivery of the Software, AT&T will start the Acceptance Test Period. 

  

	 	b.	During the Acceptance Test Period, AT&T will notify Supplier promptly in writing of any Errors found by AT&T, and Supplier will promptly correct such Errors and deliver to AT&T the resulting corrections.
AT&T shall have the right to test the Software after such corrected and/or completed Software is redelivered to AT&T, and such corrected and/or completed Software shall thereafter be subject to AT&T’s acceptance or rejection under
this Section. The Acceptance Test Period shall be extended by the greater of either (i) [***] during which [***] of the Software, or (ii) when applicable, [***]. Any Errors in the Software that [***] with the Specifications shall be addressed
in accordance with the appropriate resolution plan as set forth in Section 3.10.e. “Error Severity Level and Resolution Plan and Liquidated Damages”. 


 

	 	c.	If the Software conforms with the terms of the applicable Order during the Acceptance Test Period, AT&T shall sign and deliver a copy of an Acceptance Letter substantially in the form of Appendix F, “Acceptance
Letter”, to Supplier after the completion of the Acceptance Test Period. If AT&T fails to send an Acceptance Letter, or to inform Supplier of the rejection of the Software, within two (2) business days after the conclusion of the
Acceptance Test Period, then Supplier shall promptly notify AT&T’s IT leadership of such failure via e-mail or other writing, with a copy to AT&T’s Project Manager. If neither AT&T’s
IT leadership nor AT&T’s Project Manager responds via e-mail or other writing within [***] business days after such notice has been duly given, the Software shall be deemed to be Accepted as of the
end of such Acceptance Test Period. 

  

	 	d.	[***] any Software [***] during the Acceptance Test Period [***] prior to the date[***]. However, [***] the Acceptance Test Period shall [***]. 


 

	 	e.	Any Program Material other than Custom Software shall be deemed accepted upon delivery, subject to Supplier’s responsibility to correct Errors in such Program Material. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 16 









 Software and Professional Services Agreement 

 


	3.10	Technology Standards 

  

	 	a.	Supplier will utilize AT&T’s approved Project Management methodologies, tools and practices. Additional Amdocs procedures must be in compliance with AT&T’s current methodologies, tools and practices
for testing defect tracking systems and quality initiative approaches, and in compliance with or have an approved exception to the Technology, Strategies, and Standards (TSS) and such other processes as AT&T may implement in the future or as
AT&T may require outside of the Technology Development organization; in each case to the extent the same have been communicated to Supplier by AT&T in writing. If AT&T implements new processes or changes in existing processes that result
in a significant increase in the cost to Supplier of providing the Services, the Parties shall evaluate such changes and the associated cost using the then-applicable Change Management Process. Supplier will utilize AT&T processes for required
deliverables to AT&T, but may follow Supplier methodology and best practices for internal testing activities. 

  

	 	b.	Source Code Availability 

 Supplier shall [***] the Custom Software, [***]. Supplier shall
provide, [***], during the term of this Agreement [***], Supplier shall [***]. 
  

	 	c.	Delivery of Software 

 Software Deliveries shall be in the form selected by AT&T,
including, but not limited to, electronic data exchange, U.S. Mail or a private carrier, as agreed by the Parties and/or specified in the applicable Order. Except as otherwise agreed by the Parties and/or specified in the applicable Order, Supplier
shall deliver the Software (and any subsequent releases or upgrades of the Software purchased by AT&T) electronically, either through transfer by means of telecommunications or by copying the Software directly onto AT&T’s computer,
disk, tape or other storage medium selected by AT&T. Unless and until directed in writing by AT&T to do so, Supplier will not transfer any disks, tapes or other tangible property containing the Software (or any subsequent releases or
upgrades of the Software) to AT&T. 
  

	 	d.	Third Party Software 

 With and prior to execution of each Order, Supplier shall provide a
written list of all Third-Party Software that is part of the Software ordered by AT&T or provided by Supplier. 
  

	 	e.	Error Severity Level, Resolution Plan, and Liquidated Damages 

  

	 	i.	Supplier and AT&T shall negotiate in good faith in applicable Orders under this Agreement to include, as part of OnGoing Support Services, a Service Level Agreement and Liquidated Damages for failure to meet the
Service Level Agreement which collectively may govern certain aspects of performance of the Custom Software under the Order following Acceptance thereof. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 17 









 Software and Professional Services Agreement 

 


	 	ii.	In the case of Service Level Agreement commitments defined in the Order for which Supplier is solely responsible, Supplier shall use its best efforts to acknowledge or otherwise satisfy the commitments in the Service
Level Agreement within the performance timeframes indicated in the Order. 

  

	 	iii.	Supplier shall use its best efforts to correct any and all Errors in the Custom Software in accordance with the Error Severity Levels specified in the Order, and respond according to the escalation process, or
processes, as agreed by the Parties and specified in the Order. 

  

	 	iv.	If Supplier fails to correct Errors in the Custom Software in accordance with the Error Severity Levels specified in the Order, then in accordance with the Service Level Agreement AT&T may convene a meeting of the
Parties’ respective Project Managers to address the situation. Barring resolution of the matter by the Parties’ Project Managers, AT&T may escalate the matter per the Dispute Resolution provisions in this Agreement. Following such
escalation, [***] in the Service Level Agreement [***]. No payments, progress or otherwise, made by AT&T to Supplier after any scheduled Delivery Date shall constitute a waiver of the right to receive Liquidated Damages. If AT&T elects to
exercise its right to recover Liquidated Damages specified hereunder, Supplier shall provide a credit as shown in the column titled “Liquidated Damages” in the Service Level Agreement, and such credit(s) shall be assessed on a per Error
basis up to the aggregate cap described in the applicable Order. Such Liquidated Damages shall be provided [***] of the Service Level Agreement[***]. 

  

	 	f.	Documentation Updates 

  

	 	i.	As part of the OnGoing Support Services provided under an Order, and upon AT&T’s request, Supplier agrees to provide updates to Documentation furnished to AT&T hereunder which is related to the use and
support of the Software. Documentation shall be maintained and revised as part of such Services to reflect enhancements and corrections to the Software resulting from the issuance of a new release, including the incorporation of new or revised
operating procedures resulting from corrections to and revisions of the Software, including APIs. 

  

	 	ii.	As part of its Custom Software development Services under an Order, Supplier shall coordinate with AT&T in the manner and to the extent stated in the applicable Order to provide Documentation updates on all systems
issues, open and closed, associated with Custom Software developed for AT&T. This includes, but is not limited to, issues logs, test results, jeopardy documents, and temporary code work-arounds. 


 

	3.11	Entire Agreement 

 This Agreement constitutes the final, complete, and exclusive
expression of the Parties’ agreement on the matters contained in this Agreement. All prior written and oral negotiations and agreements, and all contemporaneous oral negotiations and agreements, between the Parties on the matters contained in
this Agreement are expressly merged into and superseded by this Agreement. The Parties do not intend that the provisions of this Agreement be explained, 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 18 









 Software and Professional Services Agreement 

 

 
supplemented, or qualified through evidence of trade usage or any prior course of dealings or any course of performance under any prior agreement. In entering into this Agreement, neither Party
has relied upon any statement, estimate, forecast, projection, representation, warranty, action or agreement of the other Party except for those expressly contained in this Agreement. There are no conditions precedent to the effectiveness of this
Agreement other than any expressly stated in this Agreement. 
  

	3.12	Force Majeure 

  

	 	a.	A Party is excused from performing its obligations under this Agreement or any Order if, to the extent that, and for so long as: 

  

	 	i.	such Party’s performance is prevented or delayed by an act or event (other than economic hardship, changes in market conditions, insufficiency of funds, or unavailability of equipment and supplies) that is beyond
its reasonable control and could not have been prevented or avoided by its exercise of due diligence; and 

  

	 	ii.	such Party gives written notice to the other Party, as soon as practicable under the circumstances, of the act or event that so prevents such Party from performing its obligations. 


 

	 	b.	By way of illustration, and not limitation, acts or events that may prevent or delay performance (as contemplated by this Section) include: acts of God or the public enemy, acts of civil or military authority,
terrorists acts, embargoes, epidemics, war, riots, insurrections, fires, explosions, earthquakes, floods, and extreme weather events. 

  

	 	c.	If Supplier is the Party whose performance is prevented or delayed for a period of [***], AT&T may elect to: 

  

	 	i.	Terminate the affected Order, without any liability to Supplier, or 

  

	 	ii.	suspend the affected Order or any part thereof for the duration of the delay; and obtain Work elsewhere and deduct from any commitment under such Order the quantity of the Work obtained elsewhere or for which
commitments have been made elsewhere; and resume performance under such Order when Supplier resumes its performance; and extend any affected Delivery Date or performance date up to the length of time Supplier’s performance was delayed or
prevented. If AT&T does not give any written notice within [***] days after receiving notice under this Section that Supplier’s performance has been delayed or prevented, this option (ii) will be deemed to have been selected.


  

	3.13	Governing Law 

 The laws of the State of Texas (excluding any laws that direct the
application of another jurisdiction’s law) govern all matters arising out of or relating to this Agreement and all of the transactions it contemplates, including its validity, interpretation, construction, performance, and enforcement. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 19 









 Software and Professional Services Agreement 

 


	3.14	Government Contract Provisions 

  

	 	a.	If an Order includes a statement that performance is intended for a government contract and to the extent any government contracting provisions are applicable to the Services to be provided by Supplier, such government
contracting provisions may include to the extent agreed by Supplier and Company: 

  

	 	i.	certain executive orders (including E.O. 11246 and E.O. 13201) and statutes (including Section 503 of the Rehabilitation Act of 1973, as amended; the Vietnam Era Veteran’s Readjustment Assistance Act of 1974;
Section 8116 of the Defense Appropriations Act for Fiscal Year 2010 (Pub. L. 111-118); and the Jobs for Veterans Act) pertaining to government contractors, Supplier shall: 


 

	 	1.	comply with such executive orders and statutes, and their implementing regulations, as amended from time to time; and 

  

	 	2.	fulfill the obligations of a contractor under the clauses incorporated by this Section. 

  

	 	b.	This Section incorporates the following statutes and rules: 

  

	 	i.	“Affirmative Action For Workers With Disabilities” (at 48 CFR §52.222-36); 

  

	 	ii.	“Employment Reports On Special Disabled Veterans, Veterans Of The Vietnam Era, and Other Eligible Veterans” (at 48 CFR §52.222-37); 


 

	 	iii.	“Equal Employment Opportunity” (at 48 CFR §52.222-26); 

  

	 	iv.	“Equal Employment Opportunity Clause” (at 41 CFR §60-1.4(a)); 

  

	 	v.	“Equal Opportunity For Special Disabled Veterans And Veterans of the Vietnam Era” (at 41 CFR §60-250.5); 


 

	 	vi.	“Equal Opportunity for Disabled Veterans, Recently Separated Veterans, Other Protected Veterans, and Armed Forces Service Medal Veterans” (at 41 CFR §60-300.5);


  

	 	vii.	“Equal Opportunity For Workers With Disabilities” (at 41 CFR §60-741.5); 

  

	 	viii.	“Prohibition of Segregated Facilities” (at 48 CFR §52.222-21); 

  

	 	ix.	“Small Business Subcontracting Plan” (at 48 CFR §52.219-9); 

  

	 	x.	“Utilization Of Small Business Concerns” (at 48 CFR §52.219-8); 

  

	 	xi.	“Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009” (FAR 52.203-15); 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 20 









 Software and Professional Services Agreement 

 


	 	xii.	“American Recovery and Reinvestment Act—Reporting Requirements” (FAR 52.204-11); 


 

	 	xiii.	“GAO/IG Access” (FAR 52.212-5(d) (Alt. II), FAR 52.214-26(c) (Alt. I), FAR 52.215-2(d)
(Alt. I)); 

  

	 	xiv.	“Davis-Bacon Act” (FAR 52.222-6); 

  

	 	xv.	“Buy American Act” (FAR 52.225-21, FAR 52.225-22, FAR 52.225-23, & FAR 52.225-24); 

  

	 	xvi.	“Whistleblower Protections” (Pub. L. No. 111-5, Section 1553); 

  

	 	xvii.	“Award term—Reporting and registration requirements under section 1512 of the Recovery Act” (2 CFR §176.50); 

  

	 	xviii.	“GAO/IG Access” (Pub. L. No. 111-5, Section 902, 1514 and 1515); 

  

	 	xix.	“Award term—Wage Rate Requirements under Section 1606 of the Recovery Act” (2 CFR §176.190); and 

  

	 	xx.	“Buy American Requirements” (2 CFR §176.140, 2 CFR §176.150, 2 CFR §176.160, & 2 CFR §176.170). 

  

	3.15	Indemnity 

  

	 	a.	Except as otherwise provided in the Section entitled “Infringement,” a Party, its Affiliates, and their agents and employees (collectively the “Indemnified Party”) shall have the right to request
from the other Party or its Affiliates, agents, or employees (collectively the “Indemnifying Party”) defense and indemnification against any third party claims for Loss for the majority of which it believes that the Indemnifying Party is
responsible alleging (1) injuries to persons, including death or disease; (2) damages to tangible property, including theft; and (3) failure to comply with Laws. The Indemnified Party shall reimburse the Indemnifying Party for that
pro rata portion of any third party claim for Loss (including Litigation Expense) resulting from an Indemnified Party’s fault (“Indemnified Party Fault”) as set forth herein. 


 

	 	b.	 Without limiting the foregoing provisions of this Section, Amdocs (as Indemnifying Party) also agrees to defend,
indemnify, hold harmless and defend AT&T (as Indemnified Party) in the event that any federal, state or local governmental agency or any of Amdocs’ current or former applicants, agents, employees or Subcontractors, or agents or employees of
Amdocs’ Subcontractors assert claims arising out of the employment relationship with Amdocs, or otherwise with respect to performance under this Agreement, including but not limited to claims, charges and actions arising under Title VII of the
Civil Rights Act of 1964, as amended, The Equal Pay Act, the Age Discrimination in Employment Act, as amended, The Rehabilitation Act, the Americans with Disabilities Act, as amended, the Fair Labor




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 21 









 Software and Professional Services Agreement 

 


	 	
Standards Act, the Family and Medical Leave Act, Workers’ Compensation laws, the National Labor Relations Act and any other applicable federal, state or local Laws. Amdocs’ duties to
indemnify, hold harmless and defend AT&T under this Section include, but are not limited to, any liability, cause of action, lawsuit, penalty, claim or demand, or administrative proceeding in which AT&T or any other Indemnified Party is
named as or alleged to be an “employer” or “joint employer” with Amdocs. The foregoing indemnity obligation shall be in addition to any other indemnity obligations of Amdocs set forth in this Agreement. 


 

	 	c.	Upon receipt of a request from any Indemnified Party for defense and indemnification under this Section, the Indemnifying Party shall have the right to determine whether, in its reasonable opinion, there is a reasonable
likelihood that Indemnified Party Fault contributed to the majority of the Loss; should the Indemnifying Party make such a determination, the Indemnifying Party shall have the right, subject to the Indemnified Party’s rights set forth below, to
refuse to defend and indemnify the Indemnified Party. The Indemnifying Party shall make such determination and notify the Indemnified Party if it refuses to defend and indemnify the Indemnified Party within [***] business days after its receipt of
the Indemnified Party’s request to the Indemnifying Party for defense and indemnification; otherwise, it shall undertake the defense. Should the Indemnifying Party refuse to defend and indemnify the Indemnified Party, the Indemnified Party
shall have the right (i) to take such action as may be necessary to defend the Indemnified Party against the claim, including filing a third party action in that case against the Indemnifying Party for contribution or other legal or equitable
rights or in an independent action against the Indemnifying Party seeking a determination that the Indemnifying Party was obligated to defend, indemnify, and hold harmless the Indemnified Party with respect to the claim and seeking any and all
remedies to which the Indemnified Party might be entitled at law or in equity and, should the court or other tribunal hearing the case under either of those scenarios determine that Indemnified Party Fault did not contribute to a majority of the
Loss, the Indemnifying Party shall promptly pay the Indemnified Party that pro-rata portion of the Indemnified Party’s Litigation Expense and any judgment against the Indemnified Party that is equivalent
to the Indemnifying Party’s fault relative to the Indemnified Party Fault or (ii) to settle the case and, either prior to or after settlement, to seek judicial determination in that case or in a separately-filed case of the amount of the
Indemnifying Party’s fault relative to the Indemnified Party Fault, and the Indemnifying Party shall be liable to the Indemnified Party for that portion of the Indemnified Party’s Litigation Expense and the settlement amount that is
equivalent to the Indemnifying Party’s fault relative to the Indemnified Party Fault as determined by the court in either such scenario. If the Indemnified Party is required to take any action to seek judicial determination of the amount of the
Indemnifying Party’s fault relative to the Indemnified Party Fault under this Agreement because of the Indemnifying Party’s failure to promptly assume the defense as set forth herein and is successful in obtaining a determination that the
Indemnified Party Fault did not contribute to the majority of the Loss, then the Indemnified Party may also recover from the Indemnifying Party any reasonable attorney’s fees and other costs of obtaining that judicial determination.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 22 









 Software and Professional Services Agreement 

 


	 	d.	Notwithstanding anything to the contrary contained herein, neither Party shall be required to indemnify the other Party from Losses resulting from claims or allegations of criminal conduct or misfeasance by the other
Party. 

  

	 	e.	The Indemnifying Party shall conduct the defense (employing counsel acceptable to the Indemnified Party), at the Indemnifying Party’s expense, against any claim, demand, suit or cause of action within the scope of
paragraph i) or paragraph ii) above, whether or not litigation is actually commenced or the allegations are meritorious and, upon the Indemnified Party’s request, keep the Indemnified Party informed as to the progress of such defense. At its
own option, the Indemnified Party may employ separate counsel, including in-house counsel, to conduct the Indemnified Party’s defense against such a claim. The Parties shall cooperate in the defense of
any such claim. The Indemnifying Party may control the defense and settlement of such a claim, but if the settlement of a claim may have an adverse effect on any Indemnified Party, then the Indemnifying Party shall not settle such claim without the
consent of the Indemnified Party, and the Indemnified Party shall not unreasonably withhold or delay its consent. To the extent that the Indemnifying Party pays any part of a judgment, award or settlement with respect to the Loss and any other
expenses related to the resolution of the Loss, including costs, interest, and reasonable Attorneys’ Fees, as a result of being self-insured or as a result of insurance coverage being insufficient to cover the amount of the judgment, award or
settlement, upon final resolution of the claim, demand, suit or cause of action, the Indemnified Party shall reimburse the Indemnifying Party for the pro-rata portion of any such payment based on the
Indemnified Party Fault relative to the Indemnifying Party’s fault. If any Indemnified Party is required to take any action to enforce its indemnity rights under this Agreement or to assume the defense of any claim, demand, suit or cause of
action for which it is entitled to receive an indemnity under this Agreement because of the Indemnifying Party’s failure to promptly assume such defense, then the Indemnified Party may also recover from the Indemnifying Party any reasonable
Attorney’s Fees and other costs of enforcing its indemnity rights or assuming such defense. 

  

	 	f.	 Notwithstanding anything to the contrary contained in this Section, the Parties intend that any amount for which
any Indemnified Party might otherwise have an obligation of reimbursement to the Indemnifying Party for its pro-rata portion pursuant to this Section will be net of any insurance proceeds or other amounts paid
by the Indemnifying Party’s insurance company or any other entity (“Insurance Proceeds”) that actually reduce the amount that the Indemnifying Party is required to pay on account of a Loss. Accordingly, the amount with respect to
which the Indemnified Party is required to reimburse the Indemnifying Party its pro-rata portion will be reduced by any Insurance Proceeds theretofore actually paid on behalf of the Indemnifying Party in
respect of the related Loss. If the Indemnifying Party receives a reimbursement required by this Section from the Indemnified Party in respect of the Indemnified Party’s pro-rata share of the amount of
any Loss and subsequently receives Insurance Proceeds or the benefit of any payments made for the Indemnifying Party or on its behalf by any insurance company or other entity with respect to such Loss, then the Indemnifying Party will pay to the
Indemnified Party, within [***] days after such receipt of Insurance Proceeds or benefit of any payments, an amount equal to the excess of the reimbursement that the Indemnifying Party received from the




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 23 









 Software and Professional Services Agreement 

 


	 	
Indemnified Party over the amount of the reimbursement that would have been due under this Section from the Indemnified Party if the Insurance Proceeds had been received, realized or recovered
before the reimbursement was made by the Indemnified Party. An insurer that would otherwise be obligated to pay any amount as a result of a Loss shall not be relieved of the responsibility with respect thereto or, by virtue of the indemnification or
reimbursement provisions hereof, have any subrogation rights with respect thereto, it being expressly understood and agreed that no insurer or any other third party shall be entitled to a “wind-fall” (i.e., a benefit they would not be
entitled to receive in the absence of the indemnification provisions) by virtue of the indemnification or reimbursement provisions hereof. The Indemnifying Party shall have a good faith obligation to seek to collect or recover any Insurance Proceeds
that may in any way be available to reduce the amount of any Loss. 

  

	 	g.	For purposes of this Section, “Loss” includes any liability, claim, demand, suit, cause of action, settlement payment, cost and expense, interest, award, judgment, damages (including punitive damages),
diminution in value, liens, fines, fees, penalties, and Litigation Expense. “Litigation Expense” means any court filing fee, court cost, arbitration fee, and each other fee and cost of investigating or defending an indemnified claim or
asserting any claim for indemnification or defense under this Agreement, including Attorney’s Fees, other professionals’ fees, and disbursements. “Attorney’s Fees” include a charge for the service of in-house counsel at the market rate for independent counsel of similar experience 

  

	3.16	Information 

  

	 	a.	 In connection with this Agreement, including Supplier’s performance of its obligations hereunder and
AT&T’s receipt of Work, either Party may find it beneficial to disclose to the other Party (which may include permitting or enabling the other Party’s access to) certain of its Information. For the purpose of this clause,
AT&T’s disclosure of Information to Supplier includes any Information that Supplier receives, observes, collects, handles, stores, or accesses, in any way, in connection with this Agreement. Information of a disclosing Party shall be deemed
to be confidential or proprietary only if it is clearly marked or otherwise identified by the disclosing Party as being confidential or proprietary, provided that if it is orally or visually disclosed (including Information conveyed to an answering
machine, voice mail box or similar medium), the disclosing Party shall designate it as confidential or proprietary at the time of such disclosure. Notwithstanding the foregoing, a disclosing Party shall not have any such obligation to so mark or
identify, or to so designate, Information that the disclosing Party discloses to or is otherwise obtained by the other Party’s employees, contractors, or representatives (i) who are located on the disclosing Party’s premises;
(ii) who access the disclosing Party’s systems; or (iii) who otherwise obtain AT&T Information and/or AT&T Customer Information in connection with this Agreement; any such Information so disclosed shall automatically be deemed
to be confidential and proprietary. Additionally, the failure to mark or designate information as being confidential or proprietary will not waive the confidentiality where it is reasonably obvious, under the circumstances surrounding disclosure,
that the Information is confidential or proprietary; any such Information so disclosed or obtained shall automatically be deemed to be confidential and proprietary. For greater certainty, Information provided by either Party to the other Party




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 24 









 Software and Professional Services Agreement 

 


	 	
prior to the Effective Date of this Agreement in connection with the subject matter hereof, including any such Information provided under a separate
non-disclosure agreement (howsoever denominated) is also subject to the terms of this Agreement. Neither Party shall disclose Information under this Agreement that includes, in any form, any of the following:
customer or employee personal information, credit card and credit related information, health or financial information, and/or authentication credentials. 

  

	 	b.	With respect to the Information of the disclosing Party, the receiving Party shall: 

  

	 	i.	hold all such Information in confidence with the same degree of care with which it protects its own confidential or proprietary Information, but with no less than reasonably prudent care; 


 

	 	ii.	restrict disclosure of such Information solely to its employees, contractors, and agents (and, in the case of AT&T, also to its Affiliates’ employees, contractors, and agents) with a need to know such
Information, advise such persons of their confidentiality obligations with respect thereto, and ensure that such persons are bound by obligations of confidentiality reasonably comparable to those imposed in this Agreement; 


 

	 	iii.	use such Information only as needed to perform its obligations (and, if AT&T is the receiving Party, to receive the benefits of the Work provided) under this Agreement; 


 

	 	iv.	except as necessary under the immediately preceding clause (3), not copy, distribute, or otherwise use any such Information or allow anyone else to copy, distribute, or otherwise use such Information; and ensure that
any and all copies bear the same notices or legends, if any, as the originals; and 

  

	 	v.	upon the disclosing Party’s request, promptly return, or destroy all or any requested portion of the Information, including tangible and electronic copies, notes, summaries, extracts, mail or other communications,
and provide written certification [***] business days to the disclosing Party that such Information has been returned or destroyed, provided that with respect to archival or back-up copies of Information that
reside on the receiving Party’s systems, the receiving Party shall be deemed to have complied with its obligations under this clause (5) if it makes reasonable efforts to expunge from such systems, or to permanently render irretrievable,
such copies. 

  

	 	c.	Except for Customer Information, neither Party shall have any obligation to the other Party with respect to Information which: 

  

	 	i.	at the time of disclosure was already known to the receiving Party free of any obligation to keep it confidential (as evidenced by the receiving Party’s written records prepared prior to such disclosure);


  

	 	ii.	is or becomes publicly known through no wrongful act of the receiving Party (such obligations ceasing at the time such Information becomes publicly known); 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 25 









 Software and Professional Services Agreement 

 


	 	iii.	is lawfully received from a third party, free of any obligation to keep it confidential; 

  

	 	iv.	is independently developed by the receiving Party or a third party, as evidenced by the receiving Party’s written records, and where such development occurred without any direct or indirect use of or access to the
Information received from the disclosing Party, or 

  

	 	v.	the disclosing Party consents in writing to be free of restriction. 

  

	 	d.	If a receiving Party is required to provide Information of a disclosing Party to any court or government agency pursuant to a written court order, subpoena, regulatory demand, request under the National Labor Relations
Act (an “NLRA Request”), or process of law, the receiving Party must, unless prohibited by applicable law, first provide the disclosing Party with prompt written notice of such requirement and reasonable cooperation to the disclosing Party
should it seek protective arrangements for the production of such Information. The receiving Party will (i) take reasonable steps to limit any such provision of Information to the specific Information required by such court or agency, and
(ii) continue to otherwise protect all Information disclosed in response to such order, subpoena, regulation, NLRA Request, or process of law. 

  

	 	e.	A receiving Party’s obligations with respect to any particular Information of a disclosing Party shall remain in effect, including after the expiration or termination of this Agreement, until such time as it
qualifies under one of the exceptions set forth in clause (c) above. Notwithstanding anything to the contrary herein, Customer Information shall remain confidential indefinitely and shall never be disclosed or used without the prior written
approval of an authorized representative of AT&T. 

  

	 	f.	Any vendors or consultants of AT&T or other third parties who are required by AT&T and authorized by Supplier in writing to have access to any Supplier Information for the purpose of providing services to
AT&T shall first sign Supplier’s non-disclosure agreement in the form attached hereto as Appendix I, Exhibit 2. In the event that such third party is a Supplier competitor (as specified by Supplier
from time to time), AT&T shall not provide such third party with access to the Supplier Information without Supplier’s express prior written consent which shall not be unreasonably withheld, conditioned, or delayed. 


 

	3.17	Infringement 

  

	 	a.	Definitions. For purposes of this Section: 

  

	 	i.	“Indemnified Parties” shall mean AT&T and its Affiliates, individually or collectively, as the case may be. 

  

	 	ii.	“Loss” shall mean any liability, loss, claim, demand, suit, cause of action, settlement payment, cost, expense, interest, award, judgment, damages (including, without limitation, punitive and exemplary damages
and increased damages for willful infringement), liens, fines, fees, penalties, and Litigation Expense. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 26 









 Software and Professional Services Agreement 

 


	 	iii.	“Litigation Expense” means any court filing fee, court cost, arbitration fee, and each other reasonable fee and cost of investigating or defending an indemnified claim or asserting any claim for
indemnification or defense under this Agreement, including without limitation reasonable attorneys’ fees and other professionals’ fees, and disbursements. 


 

	 	iv.	“Provided Elements” shall mean any products, hardware, software, interfaces, systems, content, services, processes, methods, documents, materials, data or information, or any functionality therein, provided to
any Indemnified Party by or on behalf of Supplier (including, without limitation, by any of Supplier’s sub-suppliers or distributors, but excluding only Third Party Software resold by a Third Party to
AT&T by Supplier that is governed by an applicable license agreement between AT&T and such Third Party) pursuant to this Agreement (including, without limitation, under any order, statement of work, exhibit, or other document under,
subordinate to, or referencing this Agreement). 

  

	 	b.	Obligations. 

  

	 	i.	Supplier shall indemnify, hold harmless, and defend (which shall include, without limitation, cooperating with AT&T as set forth below in the defense of) the Indemnified Parties against any Loss resulting from,
arising out of or relating to any [***], demand, claim or lawsuit brought by any third party (“Covered Claim”), regardless of whether such Covered Claim is meritorious, of: 


 

	 	1.	infringement (including, without limitation, direct, contributory and induced infringement) of any patent, copyright, trademark, service mark, or other Intellectual Property Right in connection with the Provided
Elements, including, for example, any Covered Claim of infringement based on: 

  

	 	A)	making, repair, receipt, use, importing, sale or disposal (and offers to do any of the foregoing) of Provided Elements (or having others do any of the foregoing, in whole or in part, on behalf of or at the direction of
the Indemnified Parties), or 

  

	 	B)	use of Provided Elements in [***] with products, hardware, software, interfaces, systems, content, services, processes, methods, documents, materials, data or information [***], including, for example, use in the [***]
of such Provided Elements (a “[***] Claim”); 

  

	 	2.	misappropriation of any trade secret, proprietary or non-public information in connection with the Provided Elements; 


any and all such Loss referenced in this Section b, “Obligations”, being hereinafter referred to as a “Covered Loss.” 

 

	 	ii.	 Insofar as Supplier’s obligations under paragraph b.1. result from, arise out of, or relate to a Covered
Claim that is a [***] Claim, Supplier shall be liable to pay [***] of the Covered Loss associated with such [***] Claim. [***]. If Supplier believes AT&T’s 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 27 









 Software and Professional Services Agreement 

 


	 	
assessment of Supplier’s [***] is not fair and equitable, then Supplier’s [***] shall be determined, insofar as possible, through good faith negotiation between the Parties and,
ultimately, through the dispute resolution process in this Agreement; provided, however, that a failure of the Parties to agree on Supplier’s [***] shall not relieve Supplier of its obligations to pay its [***] under this Section.


  

	 	iii.	AT&T shall have sole control over the defense of any [***] Claim. Supplier shall cooperate in every reasonable way with AT&T to facilitate the defense and may, at its option and at its own expense, participate
with AT&T in the defense with counsel of its own choosing. Where AT&T controls the defense under this paragraph, AT&T shall make good faith efforts to enter into a reasonable joint defense or common interest agreement with Supplier,
which agreement Supplier shall negotiate in good faith; provided, however, that Supplier shall not be required to provide any information or assistance to AT&T unless or until a joint defense or common interest agreement is entered into by the
Parties. 

  

	 	iv.	Insofar as Supplier’s obligations under paragraph b.1. result from, arise out of, or relate to other than a [***] Claim, Supplier shall have control of the defense of the Covered Claim. In the event that
Supplier controls the defense of the Covered Claim, Supplier shall retain as its lead counsel, subject to AT&T’s approval, one or more competent attorneys from a nationally recognized law firm who have significant experience in litigating
intellectual property claims of the type at issue; and the Indemnified Parties may, at their option and expense, participate with Supplier in the defense of such Covered Claim. Where Supplier controls the defense under this paragraph, Supplier shall
make good faith efforts to enter into a reasonable joint defense or common interest agreement with AT&T, which agreement AT&T shall negotiate in good faith; provided, however, that AT&T shall not be required to provide any information or
assistance to Supplier unless or until a joint defense or common interest agreement is entered into by the Parties. 

  

	 	v.	AT&T shall notify Supplier promptly of any Covered Claim; provided, however, that any delay in such notice shall not relieve Supplier of its obligations under this Section, except to the extent that Supplier can
show such delay actually and materially prejudiced Supplier. 

  

	 	vi.	In no event shall Supplier settle, without AT&T’s prior written consent which shall not unreasonably be withheld, any Covered Claim, in whole or in part, in a manner that would require any Indemnified Party to
discontinue or materially modify its products or services (or offerings thereof). In no event shall Supplier enter into any agreement related to any Covered Claim or to the Intellectual Property Rights asserted therein that discharges or mitigates
Supplier’s liability to the third-party claimant but fails to fully discharge all of AT&T’s liabilities as to the Covered Loss. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 28 









 Software and Professional Services Agreement 

 


	 	c.	Continued Use of Provided Elements. 

 Without in any manner limiting the foregoing
indemnification, if, as a result of a Covered Claim (other than a [***] Claim), (i) the Indemnified Parties’ rights under this Agreement are restricted or diminished; or (ii) an injunction, exclusion order, or other order from a court,
arbitrator or other competent tribunal or governmental authority preventing or restricting the Indemnified Parties’ use or enjoyment of the Provided Elements is issued, imminent, or reasonably likely to be issued, then, in addition to its other
obligations set forth in this Section, Supplier, in any case at its sole expense and at no loss, cost or damage to the Indemnified Parties or their customers, shall use commercially reasonable efforts to obtain for the Indemnified Parties the right
to continue using or conducting other activities with respect to the Provided Elements; provided that if Supplier is unable to obtain such right, Supplier shall, after consulting with and obtaining the written approval of the Indemnified Parties,
provide modified or replacement non-infringing Provided Elements that are equally suitable and functionally equivalent while retaining the quality of the original Provided Elements and complying fully with all
the representations and warranties set forth in this Agreement; provided further that if Supplier is unable in this way to provide such modified or replacement non-infringing Provided Elements, AT&T shall,
at its option: (i) terminate this Agreement with respect to the Provided Elements or (ii) require Supplier, as applicable, to remove, return, or discontinue use of the Provided Elements, and, in case of either (i) or (ii), to require
Supplier to refund to AT&T the purchase price thereof or other monies paid therefor (subject to reduction based on the amount of depreciation or amortization over the useful life of the Provided Elements at issue) and to reimburse AT&T for
any and all reasonable out-of-pocket expenses of removing, returning, or discontinuing such Provided Elements. If, as a result of a [***] Claim, (i) the Indemnified
Parties’ rights under this Agreement are restricted or diminished; or (ii) an injunction, exclusion order, or other order from a court, arbitrator or other competent tribunal or governmental authority preventing or restricting the
Indemnified Parties’ use or enjoyment of the Provided Elements is issued, imminent, or reasonably likely to be issued, and Supplier, after using commercially reasonable efforts ([***]) per [***] Claim or [***] period for all [***] Claims in
[***] period, which amounts, together with any other amounts paid with respect to such [***] Claim, [***]Claims set forth in Subsection b.ii. above), cannot provide a technically feasible non-infringing [***],
operation or use of the Provided Elements in the [***] at issue, then if Supplier obtains and provides AT&T with a written opinion from outside counsel with a national reputation in intellectual property law that no valid non-infringement or invalidity defenses exist as to the Covered Claim, AT&T shall either cease using the Provided Elements within the [***] giving rise to the [***]Claim or Supplier shall have no further
obligation to indemnify AT&T with respect to Losses associated with such [***] Claim after the date on which written opinion is provided to AT&T. 
  

	 	d.	Elimination of Charges. After AT&T ceases, as a result of actual or claimed infringement or misappropriation, to exercise the rights granted under this Agreement with respect to the Provided Elements,
AT&T has no obligation to pay Supplier any charges that would otherwise be due under this Agreement for such rights. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 29 









 Software and Professional Services Agreement 

 


	 	e.	Exceptions. Supplier shall have no liability or obligation to any of the Indemnified Parties for that portion of a Covered Loss which is based on (and only to the extent such portion is based on): 


  

	 	i.	use of the Provided Elements by the Indemnified Parties in a manner that constitutes a breach of the scope of the license terms under this Agreement or an Order; or 


 

	 	ii.	an unauthorized modification of the Provided Elements by or on behalf of an Indemnified Party; or 

  

	 	iii.	Supplier’s contractually required conformance to the Indemnified Party’s written specifications, unless any one or more of the following is true: 


 

	 	1.	the Provided Elements are or have been provided by or on behalf of Supplier to any third party at any time prior to receipt of the written specification from the Indemnified Party and other than as a result of
Supplier’s conformance to specifications provided by such third party; or 

  

	 	2.	Supplier knew that such specifications for the Provided Elements were infringing and failed to implement a technically feasible non-infringing means of complying with those
specifications; or 

  

	 	3.	the relevant specifications for the Provided Elements are of Supplier’s (or one or more of its sub-suppliers’) origin, design, or selection. 


 

	 	iv.	use of the Provided Elements by the Indemnified Parties [***] that the Indemnified Parties knew was infringing. 

  

	 	v.	a [***] Claim alleging infringement of a patent that issued after the date on which the Provided Element was provided to AT&T, if such Provided Element constitutes Paid for Development under this Agreement, except
to the extent Amdocs Pre-Existing Materials, Amdocs Independently Developed Materials, or Amdocs Mere Reconfigurations embedded therein caused the infringement. 


 

	 	f.	OTHER LIMITATIONS OF LIABILITY NOT APPLICABLE. NOTWITHSTANDING ANY OTHER PROVISION IN THIS AGREEMENT TO THE CONTRARY (AND WHETHER OR NOT SUCH A PROVISION CONTAINS LANGUAGE TO THE EFFECT THAT THE PROVISION TAKES
PRECEDENCE OVER OTHER PROVISIONS CONTRARY TO IT), WHETHER EXPRESS OR IMPLIED, NONE OF THE LIMITATIONS OF LIABILITY (INCLUDING, WITHOUT LIMITATION, ANY LIMITATIONS REGARDING TYPES OF OR AMOUNTS OF DAMAGES OR LIABILITIES) CONTAINED ANYWHERE IN THIS
AGREEMENT WILL APPLY TO SUPPLIER’S OBLIGATIONS UNDER THIS SECTION. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 30 









 Software and Professional Services Agreement 

 


	3.18	Insurance 

 The Parties agree that this Section shall apply to all existing Orders
between AT&T and Supplier. 
  

	 	a.	With respect to Supplier’s performance under this Agreement, and in addition to Supplier’s obligation to indemnify, Supplier shall comply with this Section, at its sole cost and expense. 


 

	 	b.	Supplier shall maintain insurance coverages and limits required by this Section and any additional insurance and/or bonds required by law: 


 

	 	i.	at all times during the term of this Agreement and until completion of all Services associated with this Agreement, whichever is later; and 


 

	 	ii.	with respect to any coverage maintained in a “claims-made” policy, for two (2) years following the term of this Agreement or completion of all Services associated with this Agreement, whichever is later.
If a “claims-made” policy is maintained, the retroactive date must precede the commencement of Services under this Agreement; 

  

	 	c.	Supplier shall procure the required insurance from an insurance company eligible to do business in the state or states where Services will be performed and having and maintaining a Financial Strength Rating of “A-” or better and a Financial Size Category of “VII” or better, as rated in the A.M. Best Key Rating Guide for Property and Casualty Insurance Companies, except that, in the case of
Workers’ Compensation insurance, Supplier may procure insurance from the state fund of the state where Services are to be performed. 

  

	 	d.	Supplier shall deliver to AT&T certificates of insurance stating the types of insurance and policy limits. Supplier shall provide or will endeavor to have the issuing insurance company provide at least thirty
(30) days advance written notice of cancellation, non-renewal, or reduction in coverage, terms, or limits to AT&T. Supplier shall deliver such certificates: 


 

	 	i.	prior to execution of this Agreement and prior to commencement of any Services; 

  

	 	ii.	in connection with a policy renewal or replacement, no later than fourteen (14) days following expiration of the then-current insurance policy required in this Section; and 


 

	 	iii.	for any coverage maintained on a “claims-made” policy, for two (2) years following the term of this Agreement or completion of all Services associated with this Agreement, whichever is later.


  

	 	e.	The Parties agree that: 

  

	 	i.	the failure of AT&T to demand such certificate of insurance or failure of AT&T to identify a deficiency will not be construed as a waiver of Supplier’s obligation to maintain the insurance required under
this Agreement; 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 31 









 Software and Professional Services Agreement 

 


	 	ii.	the insurance required under this Agreement does not represent that coverage and limits will necessarily be adequate to protect Supplier, nor will it be deemed as a limitation on Supplier’s liability to AT&T in
this Agreement; 

  

	 	iii.	Supplier may meet the required insurance coverages and limits with any[***] of primary and Umbrella/Excess liability insurance; and 

  


	 	iv.	Supplier is responsible for any deductible or self-insured retention. 

  

	 	f.	The insurance coverage required of Supplier by this Section shall include: 

  

	 	i.	Workers’ Compensation insurance with benefits afforded under the laws of the state in which the Services are to be performed and Employers Liability insurance with limits of at least: 


 

	 	1.	$500,000 for Bodily Injury – each accident 

  

	 	2.	$500,000 for Bodily Injury be disease – policy limits 

  

	 	3.	$500,000 for Bodily Injury by disease – each employee 

  

	 	4.	To the fullest extent allowable by Law, the policy must include a waiver of subrogation in favor of AT&T, its Affiliates, and their directors, officers and employees. 


 

	 	5.	In states where Workers’ Compensation insurance is a monopolistic state-run system, Supplier shall add Stop Gap Employers Liability with limits not less than $500,000 each
accident or disease. 

  

	 	ii.	Commercial General Liability insurance written on Insurance Services Office (ISO) Form CG 00 01 12 04 or a substitute form providing equivalent coverage, covering liability arising from premises, operations, personal
injury, products/completed operations, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract) with limits of at least: 


 

	 	1.	$2,000,000 General Aggregate limit 

  

	 	2.	$1,000,000 each occurrence limit for all bodily injury or property damage incurred in any one (1) occurrence 

  

	 	3.	$1,000,000 each occurrence limit for Personal Injury and Advertising Injury 

  

	 	4.	$2,000,000 Products/Completed Operations Aggregate limit 

  

	 	5.	$1,000,000 each occurrence limit for Products/Completed Operations 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 32 









 Software and Professional Services Agreement 

 


	 	iii.	The Commercial General Liability insurance policy must: 

  

	 	1.	include AT&T, its Affiliates, and their directors, officers, and employees as Additional Insureds. Supplier shall provide a copy of the Additional Insured endorsement to AT&T. The Additional Insured endorsement
may either be specific to AT&T or may be “blanket” or “automatic” addressing any person or entity as required by contract. A copy of the Additional Insured endorsement must be provided within sixty (60) days of execution
of this Agreement and within sixty (60) days of each Commercial General Liability policy renewal; 

  

	 	2.	include a waiver of subrogation in favor of AT&T, its Affiliates, and their directors, officers and employees; and 

  

	 	3.	be primary and non-contributory with respect to any insurance or self-insurance that is maintained by AT&T. 


 

	 	iv.	Business Automobile Liability insurance with limits of at least $1,000,000 each accident for bodily injury and property damage, extending to all owned, hired, and non-owned
vehicles. 

  

	 	v.	Umbrella/Excess Liability insurance with limits of at least $1,000,000 each occurrence and with terms and conditions at least as broad as the underlying Commercial General Liability, Business Auto Liability, and
Employers Liability policies. Umbrella/Excess Liability limits will be primary and non-contributory with respect to any insurance or self-insurance that is maintained by AT&T. 


 

	 	vi.	Fidelity or Crime insurance covering employee dishonesty, including but not limited to dishonest acts of Supplier and its employees, agents, Subcontractors and anyone under Supplier’s supervision or control.
Supplier shall be liable for money, securities or other property of AT&T in the custody, care or control of the Supplier. Supplier shall include a client coverage endorsement written for limits of a least $1,000,000 and shall include AT&T as
Loss Payee. 

  

	 	vii.	Professional Liability (Errors & Omissions) insurance with limits of at least $1,000,000 each claim or wrongful act including data security breach. 


 

	 	viii.	Property insurance with limits equal to the replacement cost of Supplier’s Business Personal Property at the location where Services are to be performed under this Agreement. The Property insurance policy will
include a waiver of subrogation in favor of AT&T, its Affiliates, and their directors, officers and employees. 

  

	 	g.	To the extent that Supplier’s Subcontractors are not covered by the insurance policies required under this Section, Supplier shall require each Subcontractor that may perform Services under this Agreement or enter
upon the AT&T Facilities or Supplier facilities to maintain coverages, requirements, and limits at least as broad as those listed in this Section from the time when the Subcontractor begins performance of Services, throughout the term of the
Subcontractor’s performance of Services and, with respect to any coverage maintained on a “claims-made” policy, for two (2) years thereafter. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 33 









 Software and Professional Services Agreement 

 


	3.19	Invoicing and Payment 

  

	 	a.	Supplier shall render an invoice for all Services rendered under an Order in accordance with the payment schedule as set forth in the Order. 


 

	 	b.	The invoice shall specify in detail, where applicable (1) quantities of each ordered item, (2) unit prices of each ordered item, (3) the estimated amount of tax per item, (4) any relevant item and
commodity codes known to Supplier, (5) total amounts for each item, (6) total estimated amount of applicable sales or use taxes, (7) discounts, (8) shipping charges, and (9) total amount due. AT&T shall pay Supplier in
accordance with the prices set forth in this Agreement within [***] days of the date of receipt of the invoice. Payment for Material or Services not conforming to the Specifications (in the event of payments due upon Acceptance), and portions of any
invoice in dispute, may be withheld by AT&T until such problem has been resolved in accordance with the provisions of this Agreement. If AT&T disputes any invoice rendered or amount paid, AT&T shall promptly so notify Supplier. The
Parties shall use their best efforts to resolve such dispute expeditiously, per the dispute resolution provisions in this Agreement. Any undisputed portion of invoices shall be resubmitted by Supplier and paid in accordance with this Agreement. In
the event that a dispute is resolved in Supplier’s favor, AT&T will pay Disputed Payment Interest (as defined below) on the withheld fees from the date such payment was initially due. 


 

	 	c.	Payment for Services performed may be either under a time and materials Order, or a fixed-bid Order. In time and materials Orders, AT&T shall compensate Supplier on the basis
of hours actually worked. In the case of fixed-bid Orders, AT&T shall compensate Supplier on the basis of the agreed fixed price. Estimates for fixed bid Orders shall be calculated based upon [***] hours
of work per month. [***]. 

  

	 	d.	Supplier agrees to accept standard, commercial methods of payment and evidence of payment obligation including, but not limited to electronic fund transfers in connection with the purchase of the Material and Services.


  

	 	e.	Supplier may assess interest on past due disputed amounts at [***] Chase Manhattan Bank as quoted in the Wall Street Journal on the date of the applicable invoice, or at the maximum interest rate allowed by law
(“Disputed Payment Interest”). 

  

	 	f.	Notwithstanding any other remedies available to Supplier under this Agreement or under applicable law, payment in arrears of more than [***] shall bear interest from the date payment is due [***] Chase Manhattan Bank as
quoted in the Wall Street Journal or at the maximum interest rate allowed by law, unless the amount in arrears is disputed in good faith and until such dispute is resolved. Additionally, and without affecting the foregoing, AT&T’s failure
to pay any undisputed payment under this Agreement within [***] after such payment becomes due shall be considered a material breach of this Agreement by AT&T, subject to the provisions of Section 3.36b, “Termination for Cause”.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 34 









 Software and Professional Services Agreement 

 


	3.20	Labor Disputes 

  

	 	a.	In the event of a labor dispute between AT&T and the union(s) representing AT&T’s employees, AT&T may exercise its right to modify the scope of Work under any Order with [***] days advance notice,
including postponing, reducing, or terminating the Services to be provided under the Order and due to be performed after the commencement of a labor dispute, provided, however, that in the event of the termination of Services pursuant to this
paragraph, such termination shall be deemed a termination for convenience and subject to the payment of any applicable early termination fees under such terminated Order. AT&T acknowledges and agrees that the exercise of such right may result in
a delay in the resumption of Services when requested by AT&T. 

  

	 	b.	The rights and obligations of the Parties under this Section are in addition to, and not a limitation of, their respective rights under the Section entitled “Amendments and Waivers”. 


 

	 	c.	Where AT&T modifies the scope of Work to include a reduction, postponement or termination of the Services to be provided, until reinstatement of such Services, the terms of any Service Level Agreements and project
delivery dates/milestones applicable to such Services shall be reasonably modified by the Parties to reflect such modification. In addition, no such modification shall relieve AT&T of its obligation to pay Supplier for any Services actually
performed by Supplier (whether before or after such modification) notwithstanding Supplier’s failure or inability to achieve any payment milestone set forth in the applicable Order as a result of such modification. 


 

	3.21	Limitation of Damages 

  

	 	a.	Exclusion of Indirect and Consequential Damages. EXCEPT AS PROVIDED IN THIS SECTION NEITHER PARTY SHALL BE LIABLE TO THE OTHER PARTY FOR INDIRECT, CONSEQUENTIAL, INCIDENTAL, SPECIAL, EXEMPLARY OR
PUNITIVE DAMAGES, INCLUDING LOST REVENUE, LOST DATA OR LOST PROFITS, ARISING OUT OF ANY BREACH OF THE OBLIGATIONS OF THIS AGREEMENT, REGARDLESS OF THE THEORY OF RECOVERY, EVEN IF SUCH PARTY HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.
HOWEVER, THE FOLLOWING ELEMENTS OF LOSS OR DAMAGE, IF PROVED, SHALL BE DEEMED DIRECT OR GENERAL DAMAGES NOT EXCLUDED OR LIMITED BY THE PRECEDING SENTENCE: 

  

	 	i.	LIABILITY, LOSS, OR DAMAGE FOR WHICH ONE PARTY IS OBLIGATED TO INDEMNIFY THE OTHER UNDER THIS AGREEMENT; 

  

	 	ii.	LOSS OR DAMAGE PROXIMATELY CAUSED BY A PARTY’S BREACH OF ITS OBLIGATIONS UNDER THE SECTION ENTITLED “INFORMATION”; AND 


 

	 	iii.	LIQUIDATED DAMAGES AND CREDITS PROVIDED UNDER ANY PROVISION OF THIS AGREEMENT. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 35 









 Software and Professional Services Agreement 

 


	 	b.	Limitation of Direct and General Damages. EXCEPT AS PROVIDED IN THIS SECTION NEITHER PARTY SHALL BE LIABLE TO THE OTHER PARTY WITH RESPECT TO ANY ORDER OR THIS AGREEMENT FOR ANY DAMAGES IN EXCESS OF
ONE MILLION DOLLARS WITH RESPECT TO ANY ORDER, OR FOR ANY DAMAGES IN EXCESS OF FIVE MILLION DOLLARS UNDER ALL ORDERS OR THIS AGREEMENT. HOWEVER, THE FOLLOWING ELEMENTS OF LOSS OR DAMAGE, IF PROVED, SHALL NOT BE EXCLUDED OR LIMITED BY THE PRECEDING
SENTENCES: 

  

	 	i.	LIABILITY, LOSS, OR DAMAGE FOR WHICH ONE PARTY IS OBLIGATED TO INDEMNIFY THE OTHER UNDER “INDEMNITY” (solely with respect to personal injury and property damage), “INFRINGEMENT OF THIRD PARTY INTELLECTUAL
PROPERTY RIGHTS,” AND “INDEPENDENT CONTRACTOR”; PROVIDED, HOWEVER, THAT, WITH RESPECT TO LOSS, LIABILITY, OR DAMAGE WHICH MAY BE COVERED BY LIABILITY INSURANCE OF THE TYPES REQUIRED IN THE SECTION ENTITLED “INSURANCE,” EACH
PARTY SHALL AND HEREBY DOES WAIVE ANY CLAIMS DAMAGES IN EXCESS OF THE LIMITS ON INSURANCE MENTIONED IN THAT SECTION; 

  

	 	ii.	LOSS OR DAMAGE PROXIMATELY CAUSED BY A PARTY’S BREACH OF ITS OBLIGATIONS UNDER THE SECTION ENTITLED “INFORMATION”; 

  

	 	iii.	SUPPLIER’S LIABILITY PURSUANT TO SECTION 3.43d.iv TO REFUND AMOUNTS PAID FOR WORK UNDER AN ORDER FOR CUSTOM SOFTWARE DEVELOPMENT, WHERE SUCH SOFTWARE FAILS ACCEPTANCE AND HAS NEVER BEEN PUT INTO PRODUCTION; IF SUCH
FAILURE HAS RESULTED SOLELY FROM SUPPLIER’S FAILURE TO PERFORM ITS OBLIGATIONS UNDER THIS AGREEMENT, SHALL BE EQUAL TO A MAXIMUM OF THE SUM OF AMOUNTS PAID BY AT&T FOR SUCH WORK, PLUS ANY LIQUIDATED DAMAGES THAT AT&T HAS RECOVERED, EVEN
IF THE LIQUIDATED DAMAGES THEMSELVES HAVE REACHED THE ONE MILLION DOLLAR LIMIT PROVIDED IN THE SECOND SENTENCE OF SECTION b ABOVE; 

  

	 	iv.	SUPPLIER’S LIABILITY FOR FAILURE TO MEET ITS WARRANTY OBLIGATIONS TO CORRECT CERTAIN ERRORS AND SUPPLIER’S LIABILITY FOR LIQUIDATED DAMAGES FOR BREACH OF A SERVICE LEVEL AGREEMENT BOTH OF WHICH ARE, HOWEVER,
SEPARATELY LIMITED AS PROVIDED IN SECTION 3.43d; AND 

  

	 	v.	AT&T’S LIABILITY TO PAY FOR SERVICES RENDERED OR EXPENSES INCURRED UNDER THIS AGREEMENT OR ANY ORDER THERETO. 

  

	3.22	Non-Exclusive Market 

 This Agreement does not
grant Supplier any right or privilege to provide to AT&T any Work of the type described in or purchased under this Agreement. Except for obligations arising under an 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 36 









 Software and Professional Services Agreement 

 

 
Order, this Agreement does not obligate AT&T to purchase or license any such Work. AT&T may contract with other manufacturers and vendors for the procurement or trial of Work comparable
to that described in or purchased under this Agreement, and AT&T may itself perform such Work. 
  

	3.23	Notices 

  

	 	a.	Each Party giving or making any notice, consent, request, demand, or other communication (each, a “Notice”) pursuant to this Agreement must give the Notice in writing and use one of the following methods, each
of which for purposes of this Agreement is a writing: in person; first class mail with postage prepaid; Express Mail, Registered Mail, or Certified Mail (in each case, return receipt requested and postage prepaid); internationally recognized
overnight courier (with all fees prepaid); or email. If Notice is given by e-mail, it must be confirmed by a copy sent by any one of the other methods or by a return email by the Addressee confirming receipt.
Each Party giving Notice shall address the Notice to the appropriate person (the “Addressee”) at the receiving Party at the address listed below: 


Amdocs, Inc. 
 1390 Timberlake
Manor Parkway 
 Chesterfield, MO 63017 

Attn: Legal Department 
 Email
Address: nacontractsadmin@amdocs.com 
 Business Number:
314-212-7000 
 AT&T Services, Inc. 

4119 Broadway 
 Room 650A16 

San Antonio, TX 78209 
 Attn:
Notices Administrator 
 Email Address: g06586@att.com 
  

	 	b.	A Notice is effective only if the Party giving notice has complied with the foregoing requirements of this Section and the Addressee has received the Notice. A Notice is deemed to have been received as follows:


  

	 	i.	If a Notice is furnished in person, or sent by Express Mail, Registered Mail, or Certified Mail, or internationally recognized overnight courier, upon receipt as indicated by the date on the signed receipt;


  

	 	ii.	If a Notice is sent by e-mail, upon successful transmission to the recipient’s email account, if such Notice is sent in time to allow it to be accessible by the Addressee
before the time allowed for giving such notice expires, and a confirmation copy is sent by one of the other methods or the Addressee confirms by return email that the email Notice has been received. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 37 









 Software and Professional Services Agreement 

 


	 	c.	The addresses and telephone numbers to which Notices may be given to the Addressees of either Party may be changed by written Notice given by such Party to the other pursuant to this Section. 


 

	3.24	Offshore Work Permitted Under Specific Conditions 

  

	 	a.	Supplier shall not perform any Services under this Agreement or allow such performance by any Subcontractor at a location outside the United States (“Offshore Location”) unless AT&T approves work to be
performed by Supplier or a Subcontractor at such Offshore Location. As of the Effective Date of the Agreement, Appendix C as attached hereto contains AT&T’s approval for the physical location where the work is to be performed, the Services
to be performed at such location, and, the identity of any Subcontractor performing such work. Prior to Supplier making any additions or deletions to the physical locations or changes in Subcontractors performing work at an Offshore Location, the
Parties shall amend Appendix C, or shall add to, or amend, the applicable Order. A change in the location where a Service is performed from one Offshore Location to another AT&T-approved Offshore Location
shall not require an amendment to Appendix C or the applicable Order. Remote access by Supplier employees or Subcontractors from an Offshore Location for the performance of Services shall be in accordance with Appendix D, Security and Offshore
Requirements. The requirements of this Section shall be in addition to Sections “3.2, “Amendments and Waivers”, and 3.44, “Work Done By Others”. 


 

	 	b.	AT&T shall have the right to withdraw its consent to the performance of work at an Offshore Location at any time in AT&T’s sole discretion for any reason, in which event the Parties shall assess cost
impacts, timing, methodology and amend the Agreement to reflect any changes reasonably required to permit Supplier to continue to perform such work at a location within the United States and the Parties shall amend the Agreement, Appendix C, and/or
the applicable Order accordingly. 

  

	 	c.	Supplier’s compliance with this Section, and all Services performed in Offshore Locations with AT&T’s consent, shall be subject to Section 3.31, “Records and Audits”. Supplier shall provide,
and shall ensure that all Subcontractors provide, AT&T with physical access to inspect all Offshore Locations. 

  

	 	d.	To the extent Supplier interconnects with, or otherwise has access to, the AT&T network, Supplier shall access, or establish network connections that would allow access, to the AT&T network from an Offshore
Location in compliance with Appendix D, “Security and Offshore Requirements” to the Agreement. 

  

	 	e.	 If Supplier or any Subcontractor, without intending to circumvent the requirements of this Section, provides any
Services under this Agreement in an Offshore Location without AT&T’s prior written consent and fails to cease providing such Services within [***] days after written notice from AT&T, such inadvertent provisioning and failure to timely
cure within said [***] days shall be a material breach of this Agreement and, in addition to any other legal rights or remedies available to AT&T at law or in equity, AT&T may immediately terminate the applicable Order under which such
Services are being provided, 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 38 









 Software and Professional Services Agreement 

 


	 	
without cost, liability or penalty to AT&T. Notwithstanding the foregoing, AT&T agrees that Supplier’s or a Subcontractor’s provision of the Services in an Offshore Location
without AT&T’s prior written consent on a transient basis (e.g., a Supplier’s employee’s provision of Services from an airport while in travel status) shall be permitted and shall not be deemed to be a material breach of this
Agreement. 

  

	 	f.	When AT&T has granted consent for Services to be performed in an Offshore Location, Supplier shall remain fully responsible for compliance with any foreign, federal, state or local law applicable to the
Supplier’s provision of such Services regardless of whether the Service is being performed by Supplier or a Subcontractor. Nothing contained within this Agreement is intended to extend, nor does it extend, any rights or benefits to any
Subcontractor, and no third party beneficiary right is intended or granted to any third party hereby. 

  

	3.25	Order of Precedence 

 The terms of this Agreement [***]. The Parties may not vary or
supplement the terms of this Agreement, in connection with any Order, except by Special Terms and Conditions upon which both Parties have agreed. When Special Terms and Conditions are included in an Order and agreed upon, such take precedence over
any inconsistent term of this Agreement, but only with reference to the transaction governed by that Order, and Special Terms and Conditions in an Order have no other force or effect. This Agreement shall govern in lieu of all other pre-printed or standardized provisions that may otherwise appear in any other paper or electronic record of either Party (such as standard terms on order or acknowledgment forms, advance shipping notices, invoices,
time sheets, and packages, shrink wrap terms, and click wrap terms). 
  

	3.26	Orders 

 AT&T may order Material and Services by submitting Orders in connection with
this Agreement that are substantially in the form of Appendix B. 
  

	3.27	Ownership of Paid-For Development, Use and Reservation of Rights 

  

	 	a.	Definitions. For purposes of this Section: 

  

	 	i.	“Amdocs Developed Work” means Items created, invented, or otherwise developed by Amdocs in the course of performance of Services under this Agreement or Order or other document referencing or
subordinate to this Agreement and for which Development Fees are paid by AT&T. Amdocs Developed Work does not include any Amdocs Pre-Existing Materials, Amdocs Independently Developed Materials or Amdocs
Mere Reconfigurations which may be provided to AT&T as part of a Deliverable. 

  

	 	ii.	“Amdocs Independently Developed Materials” means those Items that have been developed or created by Amdocs or on Amdocs’s behalf: (i) other than Amdocs Developed Work, (ii) without use of
any AT&T Provided Items, and (iii) either (a) in the course of the performance of the Services under an applicable Order or (b) independently of any Services provided under an Order provided that it meets (i) and (ii) above.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 39 









 Software and Professional Services Agreement 

 


	 	iii.	“Amdocs Pre-Existing Materials” means those Items owned by Amdocs, other than Amdocs Independently Developed Materials and Amdocs Mere Reconfigurations, to the
extent and in the form that they both existed prior to the date Amdocs began any Amdocs Developed Work under this Agreement and were created without any use of any of AT&T Provided Items. 


 

	 	iv.	“Amdocs Mere Reconfigurations” means only those specific reconfigurations of Amdocs’s Pre-Existing Materials or Amdocs Independently Developed Materials
performed by or on behalf of Supplier but only to the extent that such reconfiguration is an enhancement, modification, or update to Supplier’s Software which is strictly required to permit Supplier’s Software to function on
AT&T’s network or services platform and which does not constitute Amdocs Developed Work. For clarity, Amdocs Mere Reconfigurations includes enhancements, modifications, or updates to reuse Amdocs’s
Pre-Existing Materials or Amdocs Independently Developed Materials, which are pre-existing features from Amdocs’s more current software versions, and backport
(e.g., adapt) such features to AT&T’s versions of the Supplier Software currently deployed by AT&T. 

  

	 	v.	“AT&T Pre-Existing Materials” means those Items owned by AT&T, to the extent and in the form that they existed prior to the date any Services began under
this Agreement. 

  

	 	vi.	“AT&T Provided Items” means AT&T’s Items created by or on behalf of AT&T and directly or indirectly provided to, accessed by, or furnished to Amdocs (in any form, including, without
limitation, verbally) by or on behalf of AT&T or its third party providers in connection with this Agreement. 

  

	 	vii.	“Development Fees” means the monies charged to AT&T under this Agreement, any Order or any other document referencing this Agreement for any development Services under this Agreement. Payments not
deemed to be Development Fees under this definition shall include (i) license fees; (ii) maintenance and support fees; (iii) revenue sharing arrangements(iv) subscription fees which are recurring in nature to provide AT&T or
AT&T’s customers’ ongoing access to or usage of the Services provided by Supplier’s platform; or (v) payment of the standard purchase price for devices or other physical products which AT&T purchases from Supplier and
takes title to under this Agreement, in each case as imposed generally by Amdocs on its customers in connection with the provision of services or products. 

  

	 	viii.	“Items” means any or all inventions, discoveries, and ideas (whether patentable or not), and all works and materials, including, but not limited to, products, devices, computer programs, reports, plans,
models, prototypes, performance requirements, source codes, designs, files, specifications, texts, drawings, processes, data or other Information or Documentation in preliminary or final form, and all Intellectual Property Rights in or to any of the
foregoing. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 40 









 Software and Professional Services Agreement 

 


	 	ix.	“Intellectual Property Rights” or “IPR” means all patents (including all reissues, divisions, continuations, and extensions thereof) and patent applications, trade names, trademarks,
service marks, logos, trade dress, copyrights, trade secrets, mask works, rights in technology, data base rights, know-how, rights in content (including performance and synchronization rights), or other
intellectual property rights that are in each case protected under the Laws of any domestic or foreign governmental authority having jurisdiction. 

  

	 	x.	“Software” means a set of instructions or code that Amdocs and AT&T will provide under this Agreement intended to cause a computer to produce certain results and the associated Documentation for
such set of instructions or code. 

  

	 	xi.	“Third Party Material” means any software (i) not developed by or on behalf of AT&T, Amdocs, their agents or their contractors under an applicable Order and (ii) not owned by Amdocs or
AT&T or an Affiliate. 

  

	 	b.	Special Terms and Conditions: 

 Intellectual Property. 

 

	 	i.	Developed Works. 

  

	 	1.	Ownership. Except for any Amdocs Pre-Existing Materials, Amdocs Independently Developed Materials, and Amdocs Mere Reconfigurations that may be embedded therein (but
subject to subparagraph b. below), AT&T shall be the exclusive owner of all right, title, and interest in and to all Amdocs Developed Work (“Paid-For Development”). Amdocs shall assign or
have assigned to AT&T and hereby assigns to AT&T all Intellectual Property Rights in and to such Paid-For Development. 


 

	 	2.	License Grant to Amdocs Pre-Existing and Amdocs Independently Developed Materials. If and to the extent that Amdocs embeds any Amdocs
Pre-Existing Materials and/or Amdocs Independently Developed Materials in the Paid-For Development, subject to the payment of Development Fees as set forth in this
Agreement or in any applicable Order, Amdocs hereby grants and promises to grant and have granted to AT&T and its Affiliates a royalty-free, nonexclusive, sublicensable, assignable, transferable, irrevocable, perpetual, world-wide license in and
to the Amdocs Pre-Existing Materials or Amdocs Independently Developed Materials and any applicable Intellectual Property Rights of Amdocs to use, copy, modify, distribute, display, perform, import, make,
sell, offer to sell, and exploit (and have others do any of the foregoing on or for AT&T’s or any of its Affiliates’ behalf or benefit) the Amdocs Pre-Existing Materials or Amdocs Independently
Developed Materials, but only as embedded in the Paid-For Development by Amdocs. Any Amdocs Pre-Existing Materials and/or Amdocs Independently Developed Materials not
embedded in Paid-For-Development shall be subject to the applicable license agreement. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 41 









 Software and Professional Services Agreement 

 


	 	3.	Further Acts and Obligations. Amdocs will take or secure such action (including, but not limited to, the execution, acknowledgment, delivery and assistance in preparation of documents or the giving of testimony)
as may be reasonably requested by AT&T to evidence, transfer, perfect, vest or confirm AT&T’s right, title and interest in any Paid-For Development. Amdocs shall, in all events and without the
need of AT&T’s request, secure all Intellectual Property Rights in any Paid-For Development (and any licenses specified above in any Excluded Materials) from each employee, agent, Subcontractor or sub-supplier of Amdocs who has or will have any rights in the Paid-For Development or Excluded Materials. 


 

	 	4.	Reservation of Rights and Limited License. Except as explicitly granted in this Agreement, AT&T is not transferring or granting to Amdocs or its Affiliates any right, title, or interest in or to (or granting
to Amdocs or its Affiliates any license or other permissions in or to) any Intellectual Property Rights in or to any AT&T Pre-Existing Materials, AT&T Items, AT&T Provided Items, or Paid-For Development. Except as explicitly granted in this Agreement, Amdocs is not transferring or granting to AT&T or its Affiliates any right, title, or interest in or to (or granting to AT&T or its
Affiliates any license or other permissions in or to) any Intellectual Property Rights in or to any Amdocs Pre-Existing Materials, Amdocs Independently Developed Materials, or Amdocs Mere Reconfigurations.
AT&T Pre-Existing Materials, AT&T Provided Items, and Paid-For Development shall constitute AT&T Information under this Agreement. 


 

	 	ii.	Ownership of Pre-Existing and Independently Developed Materials. 

  

	 	1.	Subject to the licenses herein, Amdocs shall retain ownership and all right, title and interest therein and thereto of all Amdocs Pre-Existing Materials, Amdocs Independently
Developed Materials, and Amdocs Mere Reconfigurations. AT&T acknowledges that Amdocs may pursue the development of Amdocs Independently Developed Materials. 

  

	 	2.	AT&T shall retain ownership and all right, title and interest in and to all AT&T Pre-Existing Materials, AT&T Provided Items and
Paid-For Development. 

  

	3.28	Prices 

  

	 	a.	Supplier shall furnish Work at the prices set forth in Appendix A, or pursuant to firm prices quoted by Supplier for such Work. Commencing January 2018, Supplier may elect to increase the prices in Appendix A annually.
Supplier agrees to review such proposed rate increases with AT&T Global Supply Chain and AT&T Technology Development management. Such increases may not exceed the [***], as published in the month preceding the month in which the price
increase is proposed. [***]. The prices for all Work in Appendix A are subject to increase only in accordance with this Agreement, changes to which must be in writing, reviewed by AT&T management and signed by both Parties as an Amendment to
this Agreement. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 42 









 Software and Professional Services Agreement 

 


	 	b.	Supplier shall strive to proactively reduce its costs and corresponding prices for long term Work as charged to AT&T each calendar year, through the use of improved processes, supply chain economies and other cost
reduction methods. Supplier requests AT&T’s cooperation with Supplier’s efforts to reduce Supplier’s costs for long term Work. 

  

	 	c.	In the event that Supplier provides Work to AT&T through another entity with which AT&T has an agreement, such Work shall be provided at [***] the rates specified in this Agreement. 


 

	 	d.	Supplier confirms that the financial terms and conditions applicable to the Services provided under this Agreement are, as of the Effective Date of this Agreement, and, during the term of this Agreement, shall [***] For
clarity, the Parties acknowledge that the signatory is authorized by and that the written attestation represents approval from the then-current Chief Executive Officer (CEO), currently Eli Gelman, Chief Financial Officer (CFO), currently Tamar
Rapaport-Dagim, or Chief Business Officer (CBO), currently Shuky Sheffer, of Amdocs Management Ltd. 

  

	3.29	Publicity 

  

	 	a.	Supplier shall not use AT&T’s or its Affiliates’ names or any language, pictures, trademarks, service marks or symbols which could, in AT&T’s judgment, imply AT&T’s or its
Affiliates’ identity or endorsement by AT&T, its Affiliates or any of its employees in any (i) written, electronic, or oral advertising or presentation or (ii) brochure, newsletter, book, electronic database, or other written
material of whatever nature. Supplier may submit a publicity request to AT&T for written approval, which AT&T may accept or reject at its sole discretion. 


 

	 	b.	AT&T acknowledges that Supplier is a publicly traded corporation and is therefore subject to certain reporting rules that may require that Supplier publish certain matters which relate to AT&T and that Supplier
may make such factual publications or disclosures without marketing hyperbole or “puffery” as may be required by Law or the rules of any securities exchange on which it is traded. 


 

	3.30	Quality Assurance 

  

	 	a.	Quality 

  

	 	i.	For the term of this Agreement, Supplier and Supplier’s Subcontractor organization(s) will have a quality program in place. 

  

	 	ii.	CMM Level-3 Assessment. Supplier Custom Software development organization(s) that are supporting AT&T software development will obtain and maintain a CMM Level-3 Assessment, as prescribed by the Software Engineering Institute. Supplier’s OnGoing Support resources shall follow the AT&T quality assurance program and process. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 43 









 Software and Professional Services Agreement 

 


	 	b.	Testing 

  

	 	i.	Supplier shall perform or cause to be performed testing sufficient to ensure Work performs in accordance with the Specifications. 

  

	 	ii.	If testing indicates Work does not conform to the Specifications, then Supplier shall promptly notify AT&T, in writing, of such non-conformance before shipment or provision of
Work. 

  

	 	iii.	AT&T will advise Supplier whether Supplier should Deliver the non-conforming Work. 

  

	 	iv.	In the event AT&T instructs Supplier to Deliver non-conforming Work, Supplier shall not be relieved of any of its obligations hereunder, including warranty obligations.
AT&T’s receipt of any such nonconforming Work shall not constitute a waiver of any of AT&T’s rights, warranties, or remedies under this Agreement or elsewhere. 


 

	 	c.	Supplier Performance Management Program and Satisfaction Survey 

  

	 	i.	Upon AT&T’s request, Supplier shall participate in an AT&T supplier performance management program and/or satisfaction survey (“Survey”). 


 

	 	ii.	Supplier shall meet or exceed the quality performance requirements in the Survey categories applicable to Supplier. If the Survey reveals areas needing improvement. Supplier shall provide AT&T a plan addressing such
areas within [***] after Supplier’s receipt of the Survey results. 

  

	 	d.	Supplier Performance Scorecards 

 At AT&T’s request Supplier shall: 

 

	 	i.	collect data relating to Supplier’s performance on a schedule established by AT&T; 

  

	 	ii.	enter the data in AT&T’s supplier portal (website) available at: http://www.attsuppliers.com/ (subject to change) in a format designated by AT&T; and 


 

	 	iii.	cooperate fully with AT&T’s supplier performance management team to coordinate Supplier’s activities as related to the scorecards, which may include participation in feedback sessions, audits and issue
resolution.. 

  

	3.31	Records and Audits 

  

	 	a.	Supplier shall maintain complete and accurate records relating to the Work and the performance of this Agreement. AT&T through its external, independent auditors and governmental authorities shall have the right,
upon reasonable notice, to review such records (“AT&T Audits”), to verify the following: 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 44 









 Software and Professional Services Agreement 

 


	 	i.	the accuracy and integrity of Supplier’s invoices and AT&T’s payment obligations hereunder; 

  

	 	ii.	that the Work charged for was actually performed; 

  

	 	iii.	that the Services have been and are being provided in accordance with this Agreement; 

  

	 	iv.	the integrity of Supplier’s systems that process, store, support, maintain, and transmit AT&T data; 

  

	 	v.	the performance of Supplier’s Subcontractors with respect to any portion of the Services; and 

  

	 	vi.	that Supplier and its Subcontractors are complying with Laws in accordance with its obligations under this Agreement. 

  

	 	b.	Upon reasonable request, Supplier shall provide and shall require that its Subcontractors provide to AT&T, its external auditors, and governmental authorities, access, at all reasonable times and in a manner
designed to not unreasonably interrupt the ordinary business operations of Supplier or its Subcontractors, to: 

  

	 	i.	any facility at which the Services or any portion thereof are being performed; 

  

	 	ii.	systems and assets used to provide the Services or any portion thereof; 

  

	 	iii.	Supplier employees and Subcontractor employees providing the Services or any portion thereof; and 

  

	 	iv.	all relevant Supplier and Subcontractor records, including financial records relating to the invoices and payment obligations and supporting documentation, pertaining to the Services. 


AT&T’s access to the records and other supporting documentation shall include the right to inspect and photocopy Supplier’s
documentation and the documentation of its Subcontractors, and the right to inspect copies thereof outside of their physical location with appropriate safeguards, if such inspection is deemed reasonably necessary by AT&T. 

 

	 	c.	AT&T Audits may be conducted once a year (or more frequently if requested by governmental authorities who regulate AT&T’s business, if required by applicable Law or if auditors require follow-up access to complete audit inquiries or if an audit uncovers any problems or deficiencies), upon at least twenty (20) business days advance notice (unless otherwise mandated by Law). Supplier will
cooperate, and will ensure that its Subcontractors cooperate, in the AT&T Audits, and will make the information reasonably required to conduct the AT&T Audits available on a timely basis. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 45 









 Software and Professional Services Agreement 

 


	 	d.	If any such audit reveals an overcharge by Supplier, and Supplier does not successfully dispute the amount questioned by such audit, Supplier shall [***] at the at the then-current “Prime Rate” set forth in
the “Money Rates” table in The Wall Street Journal (“Prime Rate”). If any such AT&T Audit reveals an overcharge to AT&T during any 12-month period [***] paid by
AT&T hereunder during such period, then Supplier will reimburse AT&T for the reasonable cost of such AT&T Audit. In the event such an audit results in a determination that Supplier has undercharged AT&T, then AT&T shall promptly
pay to Supplier the amount of such undercharges. If, as a result of an AT&T Audit, AT&T determines that Supplier has committed a material breach of this Agreement, AT&T will notify Supplier promptly and Supplier will promptly remedy the
breach. In the event Supplier disputes the Audit finding, such dispute will be subject to escalation and dispute resolution in accordance with Section 4.5. 

  

	 	e.	Supplier will maintain and retain the records set forth in Subsection (a) for a period of three (3) years from their creation (unless a discovery or legal hold request is made with respect to such records, in
which case Supplier shall retain such records until AT&T notifies Supplier that such discovery or legal hold request has expired). Upon notification by AT&T of a discovery or legal hold request, Supplier shall fully cooperate with such
request and immediately preserve any Supplier records covered by such request and promptly provide such Supplier records requested by AT&T related to the inquiry. 


 

	 	f.	Except as provided in Subsection (d), all reasonable out-of-pocket costs and expenses incurred by AT&T in connection with an AT&T Audit shall be paid by AT&T. Supplier
shall be solely responsible for all costs and expenses incurred by Supplier in connection with its obligations under this Section. In the event that either Party requires that an audit be performed by an independent auditor, unless otherwise
specified herein, the Party requesting such independent auditor will be responsible for the costs and expenses associated with the independent auditor. 

  

	 	g.	With respect to AT&T requests for audits or inspections of Supplier Subcontractors, the following applies: 

  

	 	i.	If Supplier’s agreement with its applicable Subcontractor permits an AT&T Audit, AT&T shall be permitted to conduct such audit directly or through a third party representative. Supplier shall work with
AT&T in facilitating the Subcontractor’s cooperation for an expeditious and thorough audit or inspection. 

  

	 	ii.	If Supplier’s contract with its applicable Subcontractor precludes AT&T from directly conducting an audit or inspection, Supplier shall use reasonable best efforts to enable AT&T to perform an audit of the
Subcontractor with Supplier coordinating the audit process. Failing those efforts, Supplier shall, upon AT&T’s request, conduct the audit or inspection on behalf of AT&T, subject to terms agreed to by Supplier and AT&T for the
Subcontractor audit, such as areas to be audited, applicable fees, and the timeframe for reporting audit results to AT&T. If AT&T’s request for a Supplier audit or inspection arises from, in AT&T’s good faith opinion,
materially or consistently deficient Service provided by the Subcontractor under AT&T’s account, and the audit in both Parties’ opinions confirms such deficiencies, Supplier shall not charge AT&T a fee for the Supplier’s audit
of its Subcontractor. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 46 









 Software and Professional Services Agreement 

 


	 	h.	General Procedures. 

  

	 	i.	Notwithstanding the intended breadth of AT&T’s audit rights, AT&T shall not be given access to (i) the proprietary information of other Supplier customers, (ii) Supplier locations that are not
related to AT&T or the Services or areas of Supplier locations which are used for other Supplier customers, or (iii) Supplier’s internal costs. AT&T Audits are subject to Section 3.16, “Information”.


  

	 	ii.	In performing audits, AT&T shall avoid unnecessary disruption of Supplier’s operations and unnecessary interference with Supplier’s ability to perform the Services. 


 

	 	iii.	External auditors examining Supplier’s records shall not be any Supplier competitors. 

  

	 	iv.	All external auditors shall sign the NDA attached as Appendix I, Exhibit 1 prior to commencing the audit. 

  

	 	v.	Information provided by Supplier as part of an audit, and any reports derived from such information, shall be provided only to the AT&T personnel who are directly involved in such audit and AT&T management, and
shall be used for AT&T internal use only. 

  

	3.32	Severability 

 If any provision of this Agreement or any Order is determined to be
invalid, illegal, or unenforceable, the Parties agree that the remaining provisions of this Agreement or such Order shall remain in full force if both the economic and legal substance of the transactions contemplated by this Agreement or such Order
are not affected in any manner that is materially adverse to either Party by severing the provision determined to be invalid, illegal, or unenforceable. 
  

	3.33	Supplier Citizenship and Sustainability 

 Supplier shall conduct business with an abiding
respect for corporate citizenship, sustainability, and human rights (“Citizenship and Sustainability”). As such, to the extent Supplier has an existing Citizenship and Sustainability program, such program shall be no less stringent than
AT&T’s Principles of Conduct for Suppliers available at: http://www.attsuppliers.com/misc/SupplierSustainabilityPrinciples.pdf and the AT&T Human Rights in Communication Policy available at:
http://www.att.com/Common/about_us/downloads/Human_Rights_Communications_Policy.pdf (“AT&T Citizenship and Sustainability Policies”). In the event that Supplier does not have a Citizenship and Sustainability program, or such
program does not address all areas addressed in the AT&T Citizenship and Sustainability Policies, or there are modifications to the then-current AT&T Citizenship and Sustainability Policies, Supplier shall conduct its business operations in
a manner consistent with the AT&T Citizenship and Sustainability Policies. 
 Upon AT&T’s request, Supplier shall provide to
AT&T such information, reports, or survey responses as AT&T deems necessary to periodically monitor Supplier’s business operations in the context of Citizenship and Sustainability. Supplier shall respond to such requests within
reasonable timelines as set forth by AT&T. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 47 









 Software and Professional Services Agreement 

 


	3.34	Survival of Obligations 

 Obligations and rights under this Agreement or an Order that by
their nature would reasonably continue beyond the termination or expiration of this Agreement or an Order (including those in the Sections entitled “Compliance with Laws,” “Information,” [“Indemnity,”
“Infringement”] “Insurance,” “Ownership of Paid-For Development, Use and Reservation of Rights,” “Publicity,” “AT&T Supplier Information Security Requirements
(SISR)” and “Warranty”) will survive the termination or expiration of this Agreement or such Order. 
  

	3.35	Taxes 

  

	 	a.	Supplier shall invoice AT&T the amount of any federal excise, state, and local transaction taxes imposed upon the sale of Material and provision of Services under this Agreement. All such taxes must be stated as
separate items on a timely invoice listing the taxing jurisdiction imposing the tax. Non-taxable charges must be separately stated. AT&T shall pay all such applicable taxes to Supplier that are stated on
the Material or Services invoice submitted by Supplier. Supplier shall remit taxes to the appropriate taxing authorities. Supplier shall honor tax exemption certificates, and other appropriate documents, which AT&T may submit, pursuant to
relevant tax provisions of the taxing jurisdiction providing the exemption. 

  

	 	b.	Except as stated in Subsection c of this Section, Supplier agrees to pay, and to hold AT&T harmless from and against, any penalty, interest, additional tax, or other charge that may be levied or assessed as a result
of the delay or failure of Supplier, to pay any tax or file any return or information required by law, rule or regulation or by this Agreement to be paid or filed by Supplier. 


 

	 	c.	Upon AT&T’s request, the Parties shall consult with respect to the basis and rates upon which Supplier shall pay any taxes or fees for which AT&T is obligated to reimburse Supplier under this Agreement. If
AT&T determines that in its opinion any such taxes or fees are not payable, or should be paid on a basis less than the full price or at rates less than the full tax rate, AT&T shall notify Supplier in writing of such determinations, Supplier
shall make payment in accordance with such determinations, and AT&T shall be responsible for such determinations. If collection is sought by the taxing authority for a greater amount of taxes than that so determined by AT&T, Supplier shall
promptly notify AT&T. If AT&T desires to contest such collection, AT&T shall promptly notify Supplier. Supplier shall cooperate with AT&T where AT&T contests such determination or Supplier and AT&T may agree, where such
agreement will not be unreasonably withheld, conditioned or delayed, but in both cases, AT&T shall be responsible and shall reimburse Supplier for any tax, interest, or penalty in excess of AT&T’s determination. 


 

	 	d.	 If AT&T determines that in its opinion it has paid Supplier for any taxes in excess of the amount that
AT&T is obligated to pay Supplier under this Agreement, AT&T and Supplier shall consult in good faith to determine the appropriate method(s) of recovery of such excess 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 48 









 Software and Professional Services Agreement 

 


	 	
payments, which method(s) may include, but is not limited to, (i) Supplier immediately refunding to AT&T such excess payments, (ii) Supplier crediting any excess payments against
tax amounts or other payments due from AT&T if and to the extent Supplier can make corresponding adjustments to its payments to the relevant tax authority, and (iii) Supplier timely filing claims for refund and any other documents required
to recover any excess payments and Supplier promptly remitting to AT&T all such refunds and interest received. 

  

	 	e.	If any taxing authority advises Supplier that it intends to audit Supplier with respect to any taxes for which AT&T is obligated to reimburse Supplier under this Agreement, Supplier shall (i) promptly so notify
AT&T, (ii) afford AT&T an opportunity to participate with Supplier in such audit with respect to such taxes and (iii) keep AT&T fully informed as to the progress of such audit. Each Party shall bear its own expenses with
respect to any such audit, and the responsibility for any additional tax, interest or penalty resulting from such audit is to be determined in accordance with the applicable provisions of this Taxes Section. [***]. 


 

	 	f.	In addition to its rights under Subsections c., d., and e. above with respect to any tax, or tax controversy, covered by this Taxes Section, AT&T is entitled to contest, or AT&T and Supplier may agree that
Supplier contest, where such agreement may not be unreasonably withheld, conditioned or delayed, pursuant to applicable law and tariffs, and at its own expense, any tax previously invoiced that it is ultimately obligated to pay. Supplier shall
cooperate with AT&T and consider any request to contest. AT&T is entitled to the benefit of any refund or recovery of amounts that it has previously paid resulting from such a contest. Supplier shall cooperate in any such contest, but
AT&T shall pay all costs and expenses incurred in obtaining a refund or credit for AT&T. 

  

	 	g.	If either Party is audited by a taxing authority or other governmental entity in connection with taxes under this Taxes Section, the other Party shall reasonably cooperate with the Party being audited in order to
respond to any audit inquiries in an appropriate and timely manner, so that the audit and any resulting controversy may be resolved expeditiously. 

  

	 	h.	AT&T and Supplier shall reasonably cooperate with each other with respect to any tax planning to minimize taxes. The degree of cooperation contemplated by this Section is to enable any resulting tax planning to be
implemented and includes, but is not limited to: (i) Supplier’s installing and loading all of the Software licensed by AT&T, and retaining possession and ownership of all tangible personal property, (ii) Supplier’s
installing, loading and/or transferring the Software at a location selected by AT&T, and (iii) Supplier’s Delivery of all of the Software in electronic form. 


 

	 	i.	 Supplier and any of its affiliates, as appropriate, receiving payments hereunder shall provide AT&T with a
valid United States Internal Revenue Service (“IRS”) Form W-8BEN, W-8BEN-E,
W-8ECI, W-8EXP, W-8IMY, or W-9 (or any successor form prescribed by the IRS). AT&T
may reduce any payment otherwise due Supplier in connection with the sale of Material and provision of Services under this Agreement by the amount of any tax imposed on Supplier that AT&T is required to pay directly to a taxing or other
governmental authority (“Withholding Tax”). Alternatively, if applicable law permits, AT&T agrees that it will 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 49 









 Software and Professional Services Agreement 

 


	 	
honor a valid exemption certificate or other mandated document evidencing Supplier’s exemption from payment of, or liability for, any Withholding Tax as authorized or required by statute,
regulation, administrative pronouncement, or other law of the jurisdiction providing said exemption. AT&T shall provide Supplier with documentation evidencing withholding within a reasonable period of time. 


 

	3.36	Termination 

  

	 	a.	Termination for Convenience—Either Party may terminate this Agreement for convenience upon [***] days prior written notice to the other Party setting forth the effective date of such termination. The
termination of this Agreement for any reason shall not affect the obligations of either Party pursuant to any Orders previously executed hereunder, and the terms and conditions of this Agreement shall continue to apply to such Orders as if this
Agreement had not been terminated. 

  

	 	b.	Termination for Cause. 

  

	 	i.	Termination for Cause of the Agreement - If either Party breaches any material provision of this Agreement or breaches any material provision of an Order or group of Orders the breach of which is material to this
Agreement, and (i) if the breach is one that by its nature could be cured, and such breach is not cured within [***] days after the breaching Party receives written notice, or (ii) if the breach is one that by its nature cannot be cured,
or (iii) if the breach is a violation of Laws which has a material and adverse effect on the non- breaching Party or the performance of the Agreement, then, in addition to all other rights and remedies at
law or in equity or otherwise, the non-breaching Party shall have the right upon written notice to terminate this Agreement without any obligation or liability subject to the provisions of
Section 3.36b.iii. below. 

  

	 	ii.	Termination for Cause of an Order - If either Party breaches any material provision of an Order, and (i) if the breach is one that by its nature could be cured, and such breach is not cured within [***] days
after the breaching Party receives written notice, or (ii) if the breach is one that by its nature cannot be cured, or (iii) if the breach is a violation of Laws which has a material and adverse effect on the
non- breaching Party or the performance of the Order, then, in addition to all other rights and remedies at law or in equity or otherwise, the non-breaching Party shall
have the right upon written notice to terminate such Order without any obligation or liability subject to the provisions of Section 3.36b.iii. below. 

  

	 	iii.	 Pre-Termination Procedures – Except for a termination for
violation of Laws, prior to providing written notice of termination pursuant to Section 3.36b.i. or Section 3.36b.ii. above, executives of both Parties shall meet to discuss and address the issues relevant to the proposed termination as
follows: (1) in the event the Order or series of Orders proposed to be terminated [***], the Division President of the Amdocs AT&T Division shall meet with the AT&T Vice President, Global Supply Chain, with the option to include the CIO
or Senior Vice President of the AT&T business unit receiving Services under such Order(s); (2) in the event the Order or series of Orders proposed to be 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 50 









 Software and Professional Services Agreement 

 


	 	
terminated [***], the Amdocs Customer Business Group President shall meet with the AT&T Senior Vice President, Global Supply Chain with the option to include the AT&T President,
Technology Development; (3) in the event the Order or series of Orders proposed to be terminated [***] or the Agreement is subject to termination, the Amdocs Chief Executive Officer shall meet with the AT&T Chief Strategy Officer and
President – Technology and Operations. In the event the Order or series of Orders proposed to be terminated [***] or the Agreement is subject to termination, the Party alleging a material breach (the “Moving Party”) shall, except for
a termination for violation of Laws, prior to providing notice of termination, initiate an arbitration by providing the other Party written notice of its intent to arbitrate. The arbitration shall conducted under the rules of the American
Arbitration Association and be heard by a single arbitrator who shall by training, education, or experience have knowledge of the general subject matter of this Agreement. The arbitrator shall determine whether the breach(es) alleged by the Moving
Party justify termination for cause of the Agreement or the applicable Order(s). The arbitrator shall not have the power to vary from the provisions of this Agreement. The arbitrator shall promptly commence the arbitration proceeding with the intent
to conclude the proceedings and issue a written decision stating in reasonable detail the basis for the decision, which must be supported by law and substantial evidence, as promptly as the circumstances demand and permit, but generally no later
than [***] days after the arbitrator’s appointment. The arbitration may be conducted concurrently with any cure period or executive escalation, provided, however, that in the event the non-breaching Party
cures the breach identified in the Moving Party’s notice, the arbitration proceeding shall not continue. 

  

	 	iv.	Failure of the non-breaching Party to immediately terminate this Agreement and/or any Order (x) following a breach which continues longer than such cure period, provided such
breach has not been cured prior to the non-breaching Party’s providing notice of termination, or (y) following a breach that cannot be cured or that constitutes a violation of Laws shall not
constitute a waiver of the non-breaching Party’s rights to terminate. [***]. 

  

	 	c.	 Partial Termination – Where a provision of this Agreement permits AT&T to terminate an Order for
cause or convenience, such termination may, at AT&T’s option, be either complete or partial. In the case of a partial termination for cause, the terms of Section 3.36b. shall apply. In the case of a partial termination for convenience,
AT&T may accept a portion of the Software or Services covered by an Order, but AT&T shall in any event compensate Supplier for the Software or Services performed through the date of such partial termination for convenience of the Order. In
either event (partial termination for cause or partial termination for convenience), AT&T shall pay Amdocs for any portion of such Software or Services at the unit prices set forth in such Order (plus equitable portions of the termination
charges provided in this Agreement in the event of partial termination for convenience of an Order for Software Development or OnGoing Support), and the Parties shall utilize change management procedures as set forth in Section 3.8 to issue an
amendment to reflect such partial termination; provided, however, that, [***] any Order [***] under the Order) [***] of the Order, in which [***] the Parties shall [***] the [***] in accordance with the [***].




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 51 









 Software and Professional Services Agreement 

 


	 	
Upon receipt of AT&T’s payment in relation to a partial termination for cause or convenience, Supplier shall deliver to AT&T the applicable Work relating to the Software or Services
which has been prepared pursuant to such terminated Order. 

  

	 	d.	Termination of Related Orders. The right to terminate an Order for cause shall also include the right to terminate any other Order for convenience in accordance with this Agreement [***] the termination of the
initially terminated Order. 

  

	 	e.	Termination For Convenience of an Order. AT&T may at any time Terminate for Convenience any Order for Custom Software development prior to the Delivery Date of the Software covered by such Order, by giving
Amdocs written notice. AT&T may, at its option and without any Liability to Amdocs, Terminate for Convenience any OnGoing Support or Services Order by written notice to Amdocs. Upon receipt of any such termination notice, Supplier shall, if so
requested by AT&T, immediately cease performing work and incurring costs in connection with such Order. [***] in accordance with the applicable Order for work under such Order performed [***], all in accordance with the provisions of the
applicable Order and in accordance with Appendix A, “Prices”. [***] in the applicable Order, [***]. Upon receipt of AT&T’s payment, Supplier shall deliver to AT&T all Material, whether completed or in progress, which has been
prepared prior to the effective date of termination of such Order. 

  

	 	f.	In exercising its termination rights under Subsection 3.36e. above, AT&T will make commercially reasonable efforts to provide Supplier with at least [***] days prior notice for terminations of Orders for Custom
Software development Services and [***] days prior notice for terminations of Orders for OnGoing Support or Services; provided, however, that if AT&T determines in good faith that an Order requires [***] termination due to budget restrictions,
AT&T shall be permitted to exercise such rights [***] upon notice. 

  

	 	g.	Termination for Insolvency 

  

	 	i.	Right to Terminate. In the event that either Party (a) files for bankruptcy, (b) becomes or is declared insolvent, or is the subject of any proceedings related to its liquidation, insolvency or
the appointment of a receiver or similar officer for it, (c) makes an assignment for the benefit of all or substantially all of its creditors or (d) enters into an agreement for the composition, extension, or readjustment of substantially
all of its obligations, then the other Party may terminate this Agreement as of a date specified in a termination notice; provided, however, that [***]. If either Party elects to terminate this Agreement due to the insolvency of the other Party,
such termination will be deemed to be a termination for cause hereunder. 

  

	 	ii.	 Section 365(n). Notwithstanding any other provision of this Agreement to the contrary,
in the event that Supplier becomes a debtor under the Bankruptcy Code and rejects this Agreement pursuant to Section 365 of the Bankruptcy Code (a “Bankruptcy Rejection”), (i) any and all of the licensee and sublicensee
rights of AT&T arising under or otherwise set forth in this Agreement shall be deemed fully retained by and vested in AT&T as protected intellectual property rights under Section 365(n)(1)(B) of the




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 52 









 Software and Professional Services Agreement 

 


	 	
Bankruptcy Code and further shall be deemed to exist immediately before the commencement of the bankruptcy case in which Supplier is the debtor; (ii) AT&T shall have all of the rights
afforded to non-debtor licensees and sublicensees under Section 365(n) of the Bankruptcy Code; and (iii) to the extent any rights of AT&T under this Agreement which arise after the termination or
expiration of this Agreement are determined by a bankruptcy court to not be “intellectual property rights” for purposes of Section 365(n), all of such rights shall remain vested in and fully retained by AT&T after any Bankruptcy
Rejection as though this Agreement were terminated or expired. AT&T shall under no circumstances be required to terminate this Agreement after a Bankruptcy Rejection in order to enjoy or acquire any of its rights under this Agreement.


  

	 	iii.	AT&T Rights Upon Supplier’s Bankruptcy. In the event of Supplier’s bankruptcy or of the filing of any petition under the federal bankruptcy laws affecting the rights of Supplier which is not stayed
or dismissed within thirty (30) days of filing, in addition to the other rights and remedies set forth herein, to the maximum extent permitted by Law, AT&T will have the immediate right to retain and take possession for safekeeping all
AT&T Information, AT&T licensed Third Party Software, AT&T owned Equipment, AT&T owned Material, AT&T owned Custom Software, and all other Software, Equipment, Systems or Material to which AT&T is or would be entitled during
the term of this Agreement or upon the expiration or termination of this Agreement. Supplier shall cooperate fully with AT&T and assist AT&T in identifying and taking possession of the items listed in the preceding sentence. AT&T will
have the right to hold such AT&T Information, Software, Equipment, Systems and Material until such time as the trustee or receiver in bankruptcy or other appropriate court officer can provide adequate assurances and evidence to AT&T that
they will be protected from sale, release, inspection, publication or inclusion in any publicly accessible record, document, material or filing. Supplier and AT&T agree that without this material provision, AT&T would not have entered into
this Agreement or provided any right to the possession or use of AT&T Information or AT&T Software covered by this Agreement. 

  

	 	iv.	Rights To Assume In Bankruptcy. In the event of commencement of bankruptcy proceedings by or against AT&T, AT&T or its trustee in bankruptcy shall be entitled to assume this Agreement and shall be
entitled to retain all of AT&T’s license rights hereunder. 

  

	 	h.	Termination Upon Supplier’s Change in Control 

 This Section shall apply to all
agreements between any AT&T Entity and any Supplier Entity: 
  

	 	i.	 In the event of a change in Control of Supplier (or that portion of Supplier providing Services under this
Agreement) or the Entity that Controls Supplier (if any), where such Control is acquired, directly or indirectly, in a single transaction or series of related transactions, or all or substantially all of the assets of Supplier are acquired by any
Entity, or Supplier is merged with or into another Entity to form a new Entity, AT&T may at its option terminate this Agreement by giving Supplier at least [***] days prior notice and




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 53 









 Software and Professional Services Agreement 

 


	 	
designating a date upon which such termination shall be effective; provided, however, that AT&T shall not have this right if Amdocs Limited, (a Guernsey corporation as of the Effective Date)
retains Control of Supplier after such transaction, acquisition, merger; provided, further, however, if such change in Control of Supplier involves an AT&T competitor, AT&T may terminate this Agreement by giving Supplier at least [***] days
prior notice, and the AT&T competitor shall be prohibited from any contact with AT&T Data, AT&T Information and any and all other information about the AT&T account, including discussions with Supplier personnel regarding specifics
relating to the Services. Supplier shall not be entitled to any termination charges in connection with a termination pursuant to this Section 3.36h. For purposes of this Section, “Control” and its derivatives mean: (a) the
legal, beneficial or equitable ownership, directly or indirectly, of (i) [***] (ii) equity interests having the right to [***] or, in the event of dissolution, [***]; (b) the right to appoint, directly or indirectly, a majority of the board of
directors; (c) the right to control, directly or indirectly, the management or direction of the Entity by contract or corporate governance document; or (d) in the case of a partnership, the holding by an Entity (or one of its Affiliates)
of the position of sole general partner; and “Entity” means a corporation, partnership, joint venture, trust, limited liability company, association or other organization or entity. 


 

	 	ii.	Subject to any legal obligation of confidentiality or applicable securities laws, Supplier will provide AT&T with notice at the earliest permissible time of Supplier’s intention to make such a change of Control
and facilitate AT&T’s receipt of sufficient information about the Entity acquiring Control for AT&T to choose to exercise its termination rights described in this Section. 


 

	 	iii.	Any permitted assignee or successor in interest under this Section shall agree in writing to be bound by the terms and conditions of this Agreement. 


 

	 	iv.	Regardless of AT&T’s consent or refusal to consent to an assignment under this Section, Supplier, or its successor in interest, shall continue to perform under the terms of the Agreement until such time as the
Agreement terminates or expires. 

  

	 	i.	Termination Charges 

  

	 	i.	Except as provided below or in the applicable Order, in the event AT&T terminates any Order for convenience, AT&T shall pay Supplier, [***]. 


 

	 	ii.	AT&T is not liable to Supplier for any detriment resulting from termination of an Order for Material not specially developed or purchased for AT&T when termination of such Order occurs more than [***] days
before the Delivery Date. 

  

	 	iii.	AT&T is not liable for any termination charges in any case when termination results from the agreement of the Parties, except as otherwise agreed by the Parties. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 54 









 Software and Professional Services Agreement 

 


	 	j.	Obligations upon Expiration or Termination  

  

	 	i.	Upon expiration or termination of this Agreement or any Order, Supplier shall, upon the request of AT&T: (i) return all papers, materials and property of AT&T held by Supplier and (ii) provide
reasonable assistance as may be necessary for the orderly, non-disrupted continuation of AT&T’s business. Supplier also agrees to assist AT&T in coordinating the transfer of the provision of the
Services to a successor supplier, which shall include continuing to provide the required level of Services to the extent Supplier is able to maintain its level of personnel necessary to provide the required level of Services, until the date of
expiration or termination and providing the successor supplier with all pertinent information about the Services, subject to Section 3.16, “Information”. 


 

	 	ii.	Upon expiration or termination of this Agreement or any Order, AT&T shall, upon the request of Supplier, return all papers, materials and property of Supplier held by AT&T. Additionally, in the event of
termination of an Order due to AT&T’s breach, AT&T shall return to Supplier all Materials provided to AT&T by Supplier under such Order that are not owned by AT&T. 


 

	3.37	Third Party Administrative Services 

  

	 	a.	Supplier acknowledges that a third party administrator will perform certain administrative functions for AT&T in relation to this Agreement. Such administrative functions may include: 


 

	 	i.	Collecting and verifying certificates of insurance; 

  

	 	ii.	Providing financial analysis; 

  

	 	iii.	Verifying certifications under the Section entitled “Utilization of Minority, Women, and Disabled Veteran Owned Business Enterprises”; and 


 

	 	iv.	Collecting and verifying Supplier profile information. 

  

	 	b.	Supplier shall cooperate with such third party administrator in its performance of such administrative functions and shall provide such data as from time to time the third party administrator may reasonably request.
Further, notwithstanding any other provision of this Agreement, Supplier agrees that AT&T may provide any information regarding Supplier to such third party administrator. AT&T shall contractually require the third party administrator to
maintain confidentiality of Supplier’s information with rights to use it solely for purposes of the administrative functions it performs for AT&T. Supplier agrees to pay the third party administrator an annual fee for the performance of
these administrative functions, which annual fee shall not exceed three hundred dollars ($300.00), and a one-time set-up fee of thirty dollars ($30.00).



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 55 









 Software and Professional Services Agreement 

 


	3.38	Ownership of AT&T Data and AT&T Derived Data 

  

	 	a.	AT&T Data is the property of AT&T. To the extent needed to perfect AT&T’s ownership in AT&T Data, Supplier hereby assigns all right, title and interest in AT&T Data to AT&T. No transfer of
title in AT&T Data is implied or shall occur under this Agreement. AT&T grants to Supplier and its approved Subcontractors a license to access, use, and copy the AT&T Data, with no right to grant sublicenses, solely for the performance
of Supplier’s obligations during the Term of this Agreement and solely in compliance with AT&T’s privacy policies, including obligations relating to Customer Information as set forth in the Agreement. Supplier shall promptly return
AT&T Data, at no cost to AT&T, and in the format and on the media prescribed by AT&T (i) at any time at AT&T’s request, regardless of the expiration or termination of this Agreement, (ii) at the expiration or
termination of this Agreement, or (iii) with respect to particular AT&T Data, whenever such data is no longer needed by Supplier to perform its obligations under this Agreement. AT&T Data shall not be (a) utilized by Supplier for
any purpose other than as required to fulfill its obligations under this Agreement, (b) sold, assigned, leased, commercially exploited or otherwise provided to or accessed by third parties, whether by or on behalf of Supplier, (c) withheld
from AT&T by Supplier, or (d) used by Supplier to assert any lien or other right against or to it. Supplier shall promptly notify AT&T if Supplier believes that any use of AT&T Data by Supplier contemplated under this Agreement or
to be undertaken as part of the performance of this Agreement is inconsistent with the preceding sentence. 

  

	 	b.	AT&T shall own all right, title and interest to the AT&T Derived Data. To the extent needed to perfect AT&T’s ownership in AT&T Derived Data, Supplier hereby assigns all right, title and interest in
AT&T Derived Data to AT&T. AT&T grants to Supplier and its approved Subcontractors a license to access, use, and copy the AT&T Derived Data, with no right to grant sublicenses (except to an approved Supplier Subcontractor), solely
for the performance of Supplier’s obligations during the Term of this Agreement and solely in compliance with AT&T’s privacy policies, including obligations relating to Customer Information. Supplier shall deliver AT&T Derived Data
in the format, on the media and in the timing prescribed by AT&T. Such delivery shall be at no cost to AT&T unless the format, media, or timing prescribed by AT&T for delivery would cause Supplier to incur substantial additional costs,
in which case Supplier shall so notify AT&T and the Parties shall negotiate in good faith to determine whether the format, media, or timing can be changed to avoid Supplier’s incurring such costs or to determine whether AT&T is willing
to reimburse Supplier for such costs. If the Parties fail to agree, the Parties agree to use the dispute resolution procedures in the Agreement to resolve the dispute. For the avoidance of doubt, Supplier shall not create or develop AT&T Derived
Data after the expiration or termination of this Agreement. 

  

	 	c.	The provisions of this Section shall apply to all AT&T Data and AT&T Derived Data disclosed or otherwise provided to, or created, developed, modified, recast or processed by, Supplier on or after the Effective
Date of this Agreement. Supplier’s obligation to return AT&T Data and AT&T Derived Data upon AT&T’s request shall survive the expiration or termination of this Agreement, but shall not apply to AT&T Data and AT&T
Derived Data which, at the time of AT&T’s request for return, is no longer retained by or on behalf of Supplier. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 56 









 Software and Professional Services Agreement 

 


	3.39	Third Party Beneficiaries 

 The provisions of this Agreement are solely for the benefit
of the Parties hereto and are not intended to confer upon any person or entity, except the Parties hereto, any rights or remedies hereunder. There are no third party beneficiaries of this Agreement, and this Agreement shall not provide any third
person or entity with any remedy, claim, liability, reimbursement, claim of action or other right in excess of those existing without reference to this Agreement. 
  

	3.40	Risk of Loss 

 Risk of loss shall pass to AT&T when possession of the Material
passes, in the United States of America, (i) from Supplier or its intermediary to the carrier, if and when this Agreement or an Order requires Supplier to ship freight collect, and (ii) from the carrier to AT&T, if and when this
Agreement or the applicable Order requires Supplier to prepay for shipment. 
  

	3.41	Transaction Costs 

 Except as expressly provided in this Agreement or an Order, each
Party shall bear its own fees and expenses (including the fees and expenses of its agents, representatives, attorneys, and accountants) incurred in connection with the negotiation, drafting, execution, and performance of this Agreement and the
transactions it contemplates. 
  

	3.42	Utilization of Minority, Women, and Disabled Veteran Owned Business Enterprises 

  

	 	a.	AT&T seeks to give minority-, women- and Disabled Veteran-owned businesses the maximum opportunity to participate in the performance of its contracts; current goals are
MBE-15%, WBE-5%, and DVBE-1.5%. Supplier commits to making good faith efforts to achieve goals for the participation of MBE/WBE
and DVBE firms (as defined in Subsection e of this Section below entitled “MBE/WBE/DVBE Termination”). 

  

	 	b.	For the avoidance of doubt, these goals apply to all annual expenditures by any AT&T entity with Supplier. This includes all expenditures under all existing agreements between AT&T and Supplier. Supplier agrees
to meet in good faith to evaluate with AT&T on annual basis whether Supplier can increase participation over the life of the Agreement. 

  

	 	c.	In the event Supplier Diversity subcontracting results cannot be met by Supplier due to significant legal, regulatory or business relationship changes that have a direct and substantive negative impact on the attainment
of the Diversity commitments herein, AT&T and Supplier will jointly review the results and known causes of the diversity subcontracting shortfall in order to reach a mutually acceptable Diversity subcontracting target. In the event the Parties
cannot resolve the Diversity subcontracting targets, then the issue will be escalated as required through the following levels: 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 57 









 Software and Professional Services Agreement 

 


					
	 Level
	  	 Supplier
	  	 AT&T

	Level 1	  	Amdocs AT&T Division President	  	AVP-Global Supply Chain
	Level 2	  	President – Amdocs Customer Business Unit	  	President-Global Supply Chain

  

	 	d.	Attached hereto and incorporated herein as Appendix E, Exhibit 1 is Supplier’s completed Participation Plan outlining its MBE/WBE/DVBE goals and specific and detailed plans to achieve those goals. Supplier will
submit an updated Participation Plan annually by the first week in January. Supplier will submit MBE/WBE/DVBE Results Reports quarterly by the end of the first week following the close of each quarter, using the form attached hereto and incorporated
herein as Appendix E, Exhibit 2. Participation Plans and Results Reports will be submitted to the Prime Supplier Program Manager. 

  

	 	e.	MBE/WBE/DVBE Termination 

  

	 	i.	Supplier agrees that falsification or misrepresentation of, or failure to report a disqualifying change in, the MBE/WBE/DVBE status of Supplier or any Subcontractor utilized by Supplier, or Supplier’s failure to
comply in good faith with any MBE/WBE/DVBE utilization goals established by Supplier, or Supplier’s failure to cooperate in any investigation conducted by AT&T, or by AT&T’s agent, to determine Supplier’s compliance with this
Section, will constitute a material breach of this Agreement. In the event of any such breach, AT&T may, at its option, pursue termination through the dispute resolution procedures of Section 4.5 upon thirty (30) days’ notice
where such breach remains uncured by Supplier at the end of the notice period. Supplier acknowledges and agrees that AT&T shall not be subject to Liability, nor shall Supplier have any right to sue for damages, as a result of such termination.


  

	 	ii.	For purchases under this Agreement by Pacific Bell, Pacific Bell Directory, Pacific Bell Mobile Services, Pacific Bell Information Services, Pacific Bell Communications, and any other entity operating principally in
California (collectively “California Affiliates”), Minority and Women Business Enterprises (MBEs/WBEs) are defined as businesses which satisfy the requirements of Subsection iv of this Section below and are certified as MBEs/WBEs by the
California Public Utilities Commission Clearinghouse (“CPUC-certified”). 

  

	 	iii.	For purchases under this Agreement by any entity that is not a California Affiliate, MBEs/WBEs are defined as businesses which satisfy the requirements of Subsection iv of this Section below and are either
CPUC-certified or are certified as MBEs/WBEs by a certifying agency recognized by AT&T. 

  

	 	iv.	 MBEs/WBEs must be at least fifty-one percent (51%) owned by a minority
individual or group or by one or more women (for publicly-held businesses, at least fifty-one percent (51%) of the stock must be owned by one or more of those individuals), and the MBEs/WBEs’ management
and daily business operations must be controlled by one or 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 58 









 Software and Professional Services Agreement 

 


	 	
more of those individuals, and those individuals must be either U.S. citizens or legal aliens with permanent residence status. For the purpose of this definition, minority group members include
male or female Asian Americans, Black Americans, Filipino Americans, Hispanic Americans, Native Americans (i.e., American Indians, Eskimos, Aleuts and Native Hawaiians), Polynesian Americans, and multi-ethnic (i.e., any combination of MBEs and WBEs
where no one specific group has a fifty-one percent (51%) ownership and control of the business, but when aggregated, the ownership and control combination meets or exceeds the
fifty-one percent (51%) rule). “Control” in this context means exercising the power to make policy decisions. “Operate” in this context means actively involved in the day-to-day management of the business and not merely acting as officers or directors. 

  

	 	v.	For purchases under this Agreement by California Affiliates, DVBEs are defined as business concerns that satisfy the requirements of Subsection vii of this Section below and are certified as DVBEs by the California
State Office of Small and Minority Business (OSMB). The DVBE must be a resident of the State of California, and must satisfy the requirements of Subsection vii of this Section below. 


 

	 	vi.	For purchases under this Agreement by any entity that is not a California Affiliate, DVBEs are defined as any business concern that satisfies the requirements of Subsection vii of this Section below and is either a
defined DVBE for purchases by California Affiliates, or is certified as a DVBE by a certifying agency recognized by AT&T. 

  

	 	vii.	The DVBE must be (i) a non publicly-owned enterprise at least fifty-one percent (51%) owned by one or more disabled veterans; or (ii) a publicly-owned business in which
at least fifty-one percent (51%) of the stock is owned by one or more disabled veterans; or (iii) a subsidiary which is wholly owned by a parent corporation, but only if at least fifty-one percent (51%) of the voting stock of the parent corporation is owned by one or more disabled veterans; or (iv) a joint venture in which at least fifty-one
percent (51%) of the joint venture’s management and control and earnings are held by one or more disabled veterans. In each case, the management and control of the daily business operations must be by one or more disabled veterans. A disabled
veteran is a veteran of the military, naval or air service of the United States with a service-connected disability. “Management and control” in this context means exercising the power to make policy decisions and actively involved in the day-to-day management of the business and not merely acting as officers or directors. 

  

	3.43	Warranty 

  

	 	a.	Warranty for Custom Software. Subject to the limitations set forth in Subsection 3.43d Supplier will fix at no charge to AT&T any Error in the Custom Software created under an Order under this Agreement, which Error
is identified during the Warranty Period and results solely from the negligent or intentionally wrongful acts or omissions of Supplier. 

  

	 	i.	For purposes of this Agreement, the Warranty Period is [***] days commencing upon delivery into Acceptance Test, unless otherwise agreed in the applicable Order. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 59 









 Software and Professional Services Agreement 

 


	 	ii.	Upon agreement of the Parties, this Warranty for Custom Software development may be amended or supplemented in the Order, including via the implementation of a Service Level Agreement. 


 

	 	b.	OnGoing Support Orders 

  

	 	i.	Subject to the limitations set forth in Section 3.43d, Supplier shall perform the OnGoing Support Services in a good and workmanlike manner, at or above industry standards. Under this warranty, Supplier shall fix
Errors in the OnGoing Support Services which result solely from negligent or intentionally wrongful acts or omissions of Supplier, to the extent and in the manner as follows: 


 

	 	ii.	For Supplier’s OnGoing Support personnel which augment AT&T’s development teams by providing development work, AT&T shall be entitled to require such personnel to reperform Services containing Custom
Software Errors, at no charge to AT&T, provided such Errors (i) are reported to Supplier within [***] days commencing upon delivery into Acceptance Test, and (ii) occur as the result of Supplier’s sole responsibility.


  

	 	iii.	OnGoing Support personnel providing Production Support in a defective manner shall reperform the defective Services until such Defects are corrected, at no charge to AT&T, provided such Defect(s) are reported to
Supplier within[***] days after the work was originally delivered to AT&T, and provided AT&T did not contribute to the Defect(s). 

  

	 	iv.	Supplier’s OnGoing Support personnel shall[***]. 

  

	 	v.	In addition to the above remedies, if any Supplier OnGoing Support personnel are not performing to AT&T’s reasonable satisfaction, the Parties shall attempt to resolve problem within [***] days after the date
on which AT&T escalates the matter to Supplier’s Project Manager. [***]. 

  

	 	c.	Additional Supplier Warranties. Subject to the limitations set forth in Subsection 3.43d, Supplier additionally represents and warrants that: 


 

	 	i.	There are no actions, suits, or proceedings, pending or threatened, which will have a material adverse effect on Supplier’s ability to fulfill its obligations under this Agreement; 


 

	 	ii.	Supplier will promptly notify AT&T if, during the term of this Agreement, Supplier becomes aware of any action, suit, or proceeding, pending or threatened, which may have a material adverse effect on Supplier’s
ability to fulfill the obligations under this Agreement or any Order; 

  

	 	iii.	Supplier has all necessary skills, rights, financial resources, and authority to enter into this Agreement and related Orders and to provide or license the Material or Services; 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 60 









 Software and Professional Services Agreement 

 


	 	iv.	No consent, approval or withholding of objection is required from any entity, including any governmental authority, with respect to the entering into or the performance of this Agreement or any Order; 


 

	 	v.	The Material and Services will be provided free of any lien or encumbrance of any kind; and 

  

	 	vi.	Supplier shall not intentionally or knowingly insert into the Material any Harmful Code at any time. 

  

	 	d.	Limitations on Supplier’s Warranties. 

  

	 	i.	Supplier’s warranty obligations to correct Errors or re-perform Services pursuant to this Section or otherwise in the Agreement, coupled with any Liability for Liquidated
Damages for breach of a Service Level Agreement pursuant to an Order, shall together be limited in each Order to a total amount equal to [***] percent ([***]%) of the fees paid to Supplier under each Order. The Parties shall calculate such cap based
upon the total value of the applicable Software Development Order. Any Services performed to fix an Error or otherwise remedy a breach of warranty above the aggregate cap shall be chargeable to AT&T (i) at an hourly rate as stated in the
Order; or (ii) at a derived hourly rate for fixed bid using the per resource fixed bid rate in the Order; provided, however, Appendix A, “Prices”, will be utilized if the Order does not specify the applicable rates. The Parties shall
negotiate in good faith the required levels of allocated resources required under fixed bid Services Orders for the performance of support for non-warranty Services, including Production Support.


  

	 	ii.	AT&T acknowledges that the performance by Supplier of its obligations under this Agreement is dependent upon the performance by AT&T of certain obligations and the AT&T Responsibilities as defined in
Section 3.43f (the “AT&T Responsibilities”). To the extent that AT&T fails to comply with the AT&T Responsibilities, and such failure results in Supplier’s inability to perform its obligations, Supplier shall provide
written notice to AT&T of the failure to comply with the AT&T Responsibilities. AT&T shall be granted a period of [***] days to cure its failure to comply with the AT&T Responsibilities. If AT&T has not cured its failure within
the cure period, then Supplier is entitled to refer the matter for dispute resolution pursuant to Section 4.5. During the cure period and the pendency of the dispute resolution process, Supplier shall be relieved of its obligations and
Liability in the performance of the Services (including the warranty obligations stated above) for that portion of the Services which are impacted by AT&T’s failure to fulfill the AT&T Responsibilities. 


 

	 	iii.	If at any time during the warranty period AT&T believes there is a breach of any warranty, AT&T will notify Supplier setting forth the nature of such claimed breach. Supplier shall promptly investigate such
claimed breach, which investigation activities shall be conducted at no charge to AT&T, and shall either (i) provide Information that no breach of warranty in fact occurred or (ii) [***], promptly use its best efforts to take such action as
may be required to correct such breach under the Warranty. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 61 









 Software and Professional Services Agreement 

 


	 	iv.	AT&T’s sole remedy and Supplier’s sole obligation and Liability under the warranties stated in this Section and/or Agreement is for Supplier to correct the breach of warranty by fixing the Error, provided,
however, (i) [***] in the Order [***]; and (ii) where such fix fails to occur after reasonable opportunity to cure (as set forth in Sections 3.8, “Special Software Terms” and 3.9, “Acceptance or Rejection”) during Acceptance
Tests, and [***] Agreement, [***], in the circumstances where (x) the uncured breach is Supplier’s sole responsibility and (y) the breach is such that the Custom Software cannot pass Acceptance Tests and cannot be placed into
production. In the event of a refund under this Section, AT&T shall return all deliverables associated with the Project. THE WARRANTIES STATED HEREIN ARE EXCLUSIVE AND ARE IN LIEU OF ALL OTHER WARRANTIES, WRITTEN OR ORAL, STATUTORY, EXPRESS, OR
IMPLIED, INCLUDING WITHOUT LIMITATION, THE IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE, WHICH SUPPLIER EXPRESSLY DISCLAIMS. 

  

	 	e.	AT&T represents and warrants that: 

  

	 	i.	As of the Effective Date there are no actions, suits, or proceedings, pending or threatened, which will have a material adverse effect on AT&T’s ability to fulfill its obligations under this Agreement.


  

	 	ii.	AT&T will promptly notify Supplier if, during the term of this Agreement, AT&T becomes aware of any action, suit, or proceeding, pending or threatened, which may have a material adverse effect on AT&T’s
ability to fulfill the obligations under this Agreement or any Order. 

  

	 	iii.	No consent, approval or withholding of objection is required (or, if such consent, approval or withholding of objection is required, AT&T shall obtain it) from any entity, including any governmental authority, with
respect to the entering into or the performance of this Agreement or any Order. 

  

	 	f.	AT&T Responsibilities. AT&T shall perform the AT&T Responsibilities as specified in the Agreement and/or the applicable Order, including but not limited to the following: 


 

	 	i.	Any AT&T personnel performing services in conjunction with Supplier’s Services (either OnGoing Support or Custom Software Development) shall possess appropriate training and experience in relation to their
assigned tasks. 

  

	 	ii.	AT&T shall provide the agreed upon number and type of personnel as specified in order for purposes of properly fulfilling the tasks that AT&T undertakes in conjunction with a Project or Order. 


 

	 	iii.	AT&T shall perform its services in conjunction with any Order under this Agreement in a good and workmanlike manner, at or above industry standards. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 62 









 Software and Professional Services Agreement 

 


	 	iv.	AT&T shall correct at its expense any Error in the Software or deficiencies in the services which result solely from the negligent acts or omissions of AT&T. 


 

	 	v.	Subject to the limitations contained in Section 3.43d, and the requirement for AT&T to maintain Production Support to cover non-warranty work contained in
Section 3.43, Supplier and AT&T shall negotiate in good faith (including using executive escalation procedures where necessary) to resolve any disputes over responsibility for correction of Errors or deficiencies. 


 

	 	vi.	AT&T shall reasonably provide necessary co-operation, information, decisions and approvals requested by Supplier during the course of the Services. 


 

	 	vii.	AT&T shall install and maintain the environment for the System unless otherwise specified in the Order. 

  

	 	viii.	AT&T shall undertake reasonable efforts to ensure the co-operation of third-party vendors who are not under the direct control of Supplier, and to manage such third party
vendors as required for the performance of the Services and the Custom Software development. 

  

	 	ix.	AT&T shall provide, at no charge to Amdocs, office space suitable for Amdocs’ needs and the following services: computer terminals and associated peripherals including access to
E-mail/Internet; a communication line from AT&T’s premises to Supplier’s’ relevant development center with minimum capacity to be specified based on the number of users in the development
center; reasonable use of telephone, fax, and e-mail for business purposes; and office supplies, equipment and consumables, at AT&T’s normal standard. 


 

	3.44	Work Done By Others 

  

	 	a.	If any part of Supplier’s Work is dependent upon work performed by others or subcontracted consistent with the terms herein, Supplier shall inspect and promptly report to AT&T any known or discovered defect
that renders such other work unsuitable for Supplier’s proper performance. Supplier’s failure to so report any such known or discovered defect to AT&T shall constitute approval of such other work as fit, proper and suitable for
Supplier’s performance of its Services or provision of Material. 

  

	 	b.	Where a portion of the Work is subcontracted, Supplier remains fully responsible for performance thereof and shall be responsible to AT&T for the acts and omissions of any Subcontractor and any temporary worker
engaged by Supplier. Any use of a Subcontractor which is not an Affiliate of Supplier (but not of a Temporary Worker (as defined below)) must be either set forth in the applicable Order or otherwise communicated to AT&T before commencement of
the Work. Supplier shall endeavor to obtain and maintain insurance for acts and omissions of Subcontractors in material conformity with the Insurance Section of this Agreement. Supplier agrees to execute a subcontract with every Subcontractor which
materially conforms with the terms of this Agreement and, specifically, with the Insurance Section of this Agreement. Furthermore, Supplier agrees to have its Subcontractors under the Agreement execute the
non-disclosure agreement attached as Appendix I, Exhibit 3. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 63 









 Software and Professional Services Agreement 

 


	 	c.	The Parties agree that the Temporary Workers and Subcontractors engaged by Supplier may from time to time require access to the premises and facilities of AT&T for their participation in the performance of this
Agreement and the Orders issued hereunder, and that if so requested by Supplier, AT&T shall deal with the personnel of the Subcontractors and with any reasonable requests of the Subcontractors, in all respects as if such personnel were the
personnel, and such requests were the requests, of Supplier. 

  

	 	d.	Supplier may, in the ordinary course of business, subcontract (i) for third party services or products that are not exclusively dedicated to AT&T and that do not include regular direct contact with AT&T or
AT&T Affiliate personnel or the performance of services at AT&T sites or (ii) with temporary personnel firms for the provision of temporary contract labor (collectively, “Temporary Workers”); provided, that such Temporary
Workers possess the training and experience, competence and skill to perform the work in a skilled and professional manner. AT&T shall have no approval right with respect to such Temporary Workers. If, however, AT&T expresses dissatisfaction
with the services of a Temporary Worker, Supplier shall work in good faith to resolve AT&T’s concerns on a mutually acceptable basis and, at AT&T’s request, replace such Temporary Worker at no additional cost to AT&T.


  

	4.0	Special Terms 

  

	4.1	Access 

  

	 	a.	When appropriate, Supplier shall have reasonable access to AT&T’s premises during normal business hours, and at such other times as may be agreed upon by the Parties, to enable Supplier to perform its
obligations under this Agreement. Supplier shall coordinate such access with AT&T’s designated representative prior to visiting such premises. Supplier will ensure that only persons employed by Supplier or subcontracted by Supplier will be
allowed to enter AT&T’s premises. If AT&T requests Supplier or its Subcontractor to discontinue furnishing any person provided by Supplier or its Subcontractor from performing Work on AT&T’s premises, Supplier shall immediately
comply with such request. Such person shall leave AT&T’s premises immediately and Supplier shall not furnish such person again to perform Work on AT&T’s premises without AT&T’s written consent. The Parties agree that,
where required by governmental regulations, Supplier will submit satisfactory clearance from the U.S. Department of Defense and/or other federal, state or local authorities. 


 

	 	b.	AT&T may require Supplier or its representatives, including employees and Subcontractors, to exhibit identification credentials, which AT&T may issue, to gain access to AT&T’s premises for the
performance of Services. If, for any reason, any Supplier representative is no longer performing such Services, Supplier shall immediately inform AT&T. Notification shall be followed by the prompt delivery to AT&T of the identification
credentials, if issued by AT&T. Supplier agrees to comply with AT&T’s corporate policy requiring Supplier or its representatives, including employees and Subcontractors, to exhibit their company photo identification in addition to the
AT&T issued photo identification when on AT&T’s premises. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 64 









 Software and Professional Services Agreement 

 


	 	c.	Supplier’s representatives, including employees and Subcontractors, while on or off AT&T’s premises, will (i) protect AT&T’s material, buildings and structures, (ii) perform Work which
does not unreasonably interfere with AT&T’s business operations, and (iii) perform such Work with care and due regard for the safety, convenience and protection of AT&T, its employees, and property. 


 

	 	d.	Supplier shall use reasonable efforts to ensure that all persons furnished by Supplier work harmoniously with all others when on AT&T’s premises. 


 

	 	e.	Supplier shall comply with AT&T’s Security and Offshore Requirements as set forth in Appendix D. 

  

	4.2	Background Checks/Drug Screening 

 [***]. 

 

	 	c.	[***]. 

  

	4.3	Change Control 

 The Parties agree that all changes to this Agreement and to an Order
must be in writing and signed by the Party against whom enforcement is sought. Any change to an Order shall take the form of an amendment as described in Section 3.8, “Special Software Terms”. 

 

	4.4	Customer Information 

  

	 	a.	As between Supplier and AT&T, title to all Customer Information and customer proprietary network information (“CPNI”) (as that term is defined in Section 222 of the Communications Act of 1934, 47
U.S.C. §222, as amended (“Section 222”) shall be in AT&T. Except as otherwise provided herein, no license or rights to any Customer Information are granted to Supplier hereunder. 


 

	 	b.	Supplier acknowledges that Customer Information received may be subject to certain privacy laws and regulations and requirements, including requirements of AT&T provided or made available to Supplier. Supplier shall
consider Customer Information to be private, sensitive and confidential. Accordingly, with respect to Customer Information, Supplier shall comply with all applicable privacy laws and regulations and requirements, including, but not limited to, the
CPNI restrictions contained in Section 222. Accordingly, Supplier shall: 

  

	 	i.	not use any CPNI to market or otherwise sell products to AT&T’s customers, except to the extent necessary for the performance of Services for AT&T or as otherwise approved or authorized by AT&T in this
Agreement or in writing; 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 65 









 Software and Professional Services Agreement 

 


	 	ii.	make no disclosure of Customer Information to any party other than AT&T, except to the extent necessary for the performance of Services for AT&T or except such disclosure required under force of law; provided
that Supplier shall provide AT&T with notice immediately upon receipt of any legal request or demand by a judicial, regulatory or other authority or third party to disclose or produce Customer Information; Supplier shall furnish only that
portion of the Customer Information that it is legally required to furnish and shall provide reasonable cooperation to AT&T should AT&T exercise efforts to obtain a protective order or other confidential treatment with respect to such
Customer Information; 

  

	 	iii.	not incorporate any Customer Information into any database other than in a database maintained exclusively for the storage of AT&T’s Customer Information; 


 

	 	iv.	not incorporate any data from any of Supplier’s other customers, including Affiliates of AT&T, into AT&T’s customer database; 


 

	 	v.	make no use whatsoever of any Customer Information for any purpose except to comply with the terms of this Agreement; 

  

	 	vi.	make no sale, license or lease of Customer Information to any other party; 

  

	 	vii.	restrict access to Customer Information to only those employees of Supplier or Subcontractors that require access in order to perform Services under this Agreement; 


 

	 	viii.	prohibit and restrict access or use of Customer Information by any of Supplier’s other customers, Supplier’s Affiliates, or third parties except as may be agreed otherwise by AT&T; 


 

	 	ix.	promptly return all Customer Information to AT&T upon expiration or termination of this Agreement or applicable schedule or Order, unless expressly agreed or instructed otherwise by AT&T; and 


 

	 	x.	immediately notify AT&T upon Supplier’s awareness of (i) any breach of the above-referenced provisions, (ii) any disclosure (inadvertent or otherwise) of Customer Information to any third party not
expressly permitted herein to receive or have access to such Customer Information, or (iii) a breach of, or other security incident involving, Supplier’s systems or network that could cause or permit access to Customer Information
inconsistent with the above-referenced provisions, and such notice shall include the details of the breach, disclosure or security incident. Supplier shall fully cooperate with AT&T in determining, as may be necessary or appropriate, actions
that need to be taken including, but not limited to, the full scope of the breach, disclosure or security incident, corrective steps to be taken by Supplier, the nature and content of any customer notifications, law enforcement involvement, or
news/press/media contact etc., and Supplier shall not communicate directly with any AT&T customer without AT&T’s consent, which such consent shall not be unreasonably withheld. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 66 









 Software and Professional Services Agreement 

 


	4.5	Dispute Resolution 

  

	 	a.	Informal Dispute Resolution. 

 Prior to the initiation of formal dispute resolution
procedures with respect to any dispute, other than as provided in this Section, the Parties shall first attempt to resolve such dispute informally, as follows: 
  

	 	i.	Initial Effort. The Parties agree that they shall attempt in good faith to resolve all disputes by informal discussion. In the event of a dispute that is not resolved or resolvable through informal discussion,
either Party may refer the dispute for resolution to the senior corporate executives specified in Section 4.5a.v. below upon written notice to the other Party. 


 

	 	ii.	Escalation. Within seven (7) business days of a notice under Section 4.5a.i. above referring a dispute for resolution by senior corporate executives, the AT&T Contract Office and the Supplier Account
Office will each prepare and provide to a Supplier Division President and to AT&T Global Supply Chain and AT&T Technology Development executive leadership, respectively, summaries of the relevant information and background of the dispute,
along with any appropriate supporting documentation, for their review. The designated senior corporate executives will confer as often as they deem reasonably necessary in order to gather and furnish to the other all information with respect to the
matter in issue which the Parties believe to be appropriate and germane in connection with its resolution. The designated senior corporate executives shall discuss the problem and negotiate in good faith in an effort to resolve the dispute without
the necessity of any formal proceeding. The specific format for the discussions will be left to the discretion of the designated senior corporate executives, but may include the preparation of agreed-upon statements of fact or written statements of
position. 

  

	 	iii.	Provision of Information. During the course of negotiations under this Section, all reasonable requests made by one Party to another for non-privileged information, reasonably
related to the dispute, will be honored in order that each of the Parties may be fully advised of the other’s position. All negotiation shall be strictly confidential and used solely for the purposes of settlement. Any materials prepared by one
Party for these proceedings shall not be used as evidence by the other Party in any subsequent arbitration or litigation; provided, however, the underlying facts supporting such materials may be subject to discovery. 


 

	 	iv.	Prerequisite to Formal Proceedings. Formal proceedings for the resolution of a dispute may not be commenced until the earlier of: (i) the designated senior corporate executives under Section 4.5a.i. above
concluding in good faith that amicable resolution through continued negotiation of the matter does not appear likely; or (ii) [***]days after the notice under Section 4.5a.i. above referring the dispute to designated senior corporate
executives. The time periods specified in this Section 4.5a. shall not be construed to prevent a Party from instituting, and a Party is authorized to institute, formal proceedings earlier to (A) avoid the expiration of any applicable
limitations period, (B) preserve a superior position with respect to other creditors, or (C) address a dispute to the extent subject to equitable or injunctive relief. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 67 









 Software and Professional Services Agreement 

 


	 	v.	Additional Escalation. In addition to the dispute resolution provisions contained in this Section 4.5a., in connection with any exercise of its termination rights under Section 3.36, “Termination”,
AT&T will, no less than [***] days prior to the effective date of such termination, but without extending any applicable time frames specified in the Agreement, provide Supplier with the right to have its Chief Executive Officer address the
relevant issues with AT&T’s then-current Chief Strategy Officer/Division President – AT&T Technology and Operations. 

  

	 	b.	Arbitration. 

  

	 	i.	Except for a claim or controversy regarding the existence, validity or ownership of Intellectual Property Rights, and without limiting either Party’s right to seek appropriate injunctive relief in the event of a
breach or threatened breach of this Agreement, any controversy or claim arising out of or relating to this Agreement, or any breach thereof, which cannot be resolved using the procedures set forth above in Section 4.5 a. shall be finally
resolved under the Commercial Arbitration Rules of the American Arbitration Association then in effect. 

  

	 	ii.	The Arbitration shall take place in New York, New York, and shall apply the law of the State of Texas. The decision of the arbitrators shall be final and binding and judgment on the award may be entered in any court of
competent jurisdiction. The arbitrators shall be instructed to state the reasons for their decisions in writing, including findings of fact and law. The arbitrators shall be bound by the warranties, limitations of liability and other provisions of
this Agreement. Except with respect to the provisions of this Agreement that provide for injunctive relief rights, such arbitration shall be a precondition to any application by either Party to any court of competent jurisdiction. 


 

	 	iii.	Within twenty (20) business days after delivery of written notice (“Notice of Dispute”) by one Party to the other in accordance with this Section, the Parties each shall use good faith efforts to
agree upon one (1) arbitrator. If the Parties are not able to agree upon one (1) arbitrator within such period of time, the Parties each shall within ten (10) business days: (i) appoint one (1) arbitrator who has at no time
ever represented or acted on behalf of either of the Parties, and is not otherwise affiliated with or interested in either of the Parties and (ii) deliver written notice of the identity of such arbitrator and a copy of his or her written
acceptance of such appointment to the other Party. If either Party fails or refuses to appoint an arbitrator within such ten (10) business day period, the single arbitrator appointed by the other Party shall decide alone the issues set out in
the Notice of Dispute. Within ten (10) business days after such appointment and notice, such arbitrators shall appoint a third arbitrator. In the event that the two (2) arbitrators fail to appoint a third arbitrator within ten
(10) business days of the appointment of the second arbitrator, either arbitrator or either Party may apply for the appointment of a third arbitrator to the American Arbitration Association. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 68 









 Software and Professional Services Agreement 

 


	 	iv.	All arbitrators selected pursuant to this Section shall be practicing attorneys with at least five (5) years of experience in technology law applicable to the Services. Any such appointment shall be binding upon
the Parties. The Parties shall use best efforts to set the arbitration within sixty (60) days after selection of the arbitrator or arbitrators, as applicable, but in no event shall the arbitration be set more than ninety (90) days after
selection of the arbitrator or arbitrators, as applicable. Discovery as permitted by the Federal Rules of Civil Procedure then in effect will be allowed in connection with arbitration to the extent consistent with the purpose of the arbitration and
as allowed by the arbitrator or arbitrators, as applicable. The decision or award of the arbitrator or the majority of the three arbitrators, as applicable, shall be rendered within fifteen (15) days after the conclusion of the hearing, shall
be in writing, shall set forth the basis therefore, and shall be final, binding and nonappealable upon the Parties and may be enforced and executed upon in any court having jurisdiction over the Party against whom the enforcement of such decision or
award is sought. Each Party shall bear its own arbitration costs and expenses and all other costs and expenses of the arbitration shall be divided equally between the Parties; provided, however, the arbitrator or arbitrators, as applicable, may
modify the allocation of fees, costs and expenses in the award in those cases where fairness dictates other than such allocation between the Parties. 

  

	4.6	Electronic Data Interchange (EDI) 

  

	 	a.	At the request of AT&T, the Parties shall exchange Orders, payments, acknowledgements, invoices, remittance notices, and other records (“Data”) electronically, in place of tangible documents. In such case,
AT&T shall also designate whether the Parties shall exchange Data by direct electronic or computer systems communication between AT&T and Supplier, or indirectly through third party service providers with which either Party may contract or a
single AT&T designated third party service provider with which each Party shall contract independently (“Provider”), to translate, forward and/or store such Data. If the Parties exchange Data directly, they agree to exchange it in
accordance with the Telecommunications Industry Forum EDI Guidelines for use of American National Standards Institute (ANSI) Accredited Standards Committee X12 transaction sets, unless they mutually agree to a proprietary format or another standard
such as Extensible Markup Language (XML). 

  

	 	b.	The following additional conditions apply to any such exchanges: 

  

	 	i.	Garbled Transmissions: If any Data is received in an unintelligible, electronically unreadable, or garbled form, the receiving Party shall promptly notify the originating Party (if identifiable from the received Data)
in a reasonable manner. In the absence of such notice, the originating Party’s record of the contents of such Data shall control. 

  

	 	ii.	Signatures: Each Party will incorporate into each EDI transmission an electronic identification consisting of symbols or codes (“Signature”). Each Party agrees that any predetermined Signature of such Party
included in or affixed to any EDI transmission shall be sufficient to verify that such Party originated, “signed” and “executed” such transmission. Neither Party shall disclose to any unauthorized person the Signatures of the
Parties hereto. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 69 









 Software and Professional Services Agreement 

 


	 	iii.	Statute of Frauds: The Parties expressly agree that all Data transmitted pursuant to this Section shall be deemed to be a “writing” or “in writing” for purposes of
Section 2-201 of the Uniform Commercial Code (“UCC”) or any other applicable Law requiring that certain agreements be in writing and signed by the party to be bound thereby. Any such Data
containing or having affixed to it a Signature shall be deemed for all purposes: (i) to have been “signed” and “executed”; and (ii) to constitute an “original” when printed from electronic files or records
established and maintained in the normal course of business. 

  

	 	iv.	Method of Exchange: Each Party shall be responsible for its own costs to provide and maintain the equipment, software and services necessary to effectively and reliably transmit and receive Data, and the associated
charges of any Provider with which it contracts. Supplier shall be solely responsible for the cost of storing its information or Data on a Provider’s computer network, which may be retrieved by AT&T at no additional charge to AT&T by
Supplier. Either Party may change a Provider upon [***] days’ prior written notice to the other Party, except that if a single Provider for both Parties has been designated by AT&T, then AT&T may change the Provider upon [***]
days’ prior written notice to Supplier. 

  

	 	v.	Warranty of Data Integrity: Supplier represents and warrants that Data and/or information either transmitted to AT&T by Supplier or stored by Supplier on a Provider’s network for access by AT&T a) does not
knowingly or intentionally contain any Harmful Code or Vulnerability, and b) does not knowingly or intentionally infringe or violate any third party’s copyright, patent, trademark, trade secret or other proprietary rights or rights of publicity
or privacy. 

  

	4.7	Entry on AT&T Property 

  

	 	a.	If the performance of the Services provided hereunder requires Supplier’s entry upon property owned or controlled by AT&T, Supplier is hereby notified that AT&T presumes for safety planning purposes that
all tile and sheet/rolled vinyl flooring contains asbestos unless verified otherwise through sampling of the material and that AT&T-owned buildings constructed prior to 1981 may contain other asbestos
containing materials (“ACM”) and/or presumed asbestos containing materials (“PACM”). All AT&T buildings, regardless of age, may also contain both natural and manmade conditions and/or activities involving risk of harm.
AT&T has not inspected such property for the purposes of this Agreement and has not taken any efforts to discover or make safe dangerous conditions or activities for the purpose of Supplier’s performance of Services. 


 

	 	b.	 If the performance of the Services provided hereunder requires disturbance of ACM/PACM other than flooring
material (surfacing/fireproofing coatings, thermal system insulation (TSI) or other suspect materials), then Supplier must contact the project manager and request records to determine the presence, location and quantity of ACM/PACM in or adjacent to




  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 70 









 Software and Professional Services Agreement 

 


	 	
which Supplier’s employees may reasonably be expected to work. At AT&T’s discretion, the project manager may supply records that indicate which areas, if any, of the premises
contain ACM. If AT&T does not provide records or does not know if the premises contain ACM, the material will be presumed to be asbestos containing until proven otherwise. If records regarding the presence, location, and quantity of ACM do not
exist, the project manager may arrange for a survey of materials that may be disturbed to determine the presence, location, and quantity of asbestos. If AT&T is aware that ACM or PACM is indicated in materials that may be disturbed, AT&T
will advise Supplier of the presence, location and quantity of all known ACM and/or PACM at the work site. Supplier will have no obligation to provide Services in areas of premises containing ACM and/or PACM if its work could potentially disturb the
ACM/PACM, except work requiring the drilling or cutting/lifting of asbestos containing flooring in accordance with paragraph e below. Supplier will not be liable for any liquidated damages related to any delay associated with AT&T’s failure
or delay in providing Supplier with information related to the presence, location and quantity of ACM/PACM. 

  

	 	c.	If ACM or PACM is indicated on AT&T’s premises, it is AT&T’s responsibility to assure that the ACM/PACM does not present a hazard while Supplier conducts work operations on the premises. If it is
determined that Supplier’s work, other than drilling or cutting/lifting of asbestos-containing flooring, will potentially disturb ACM/PACM, releasing asbestos fibers into the air, AT&T must have a contractor meeting the requirements of
applicable Laws remove the asbestos prior to Supplier’s performing work in the area. 

  

	 	d.	Upon entering AT&T’s premises, Supplier shall be responsible for inspecting the Services site for visually obvious unsafe conditions and taking the necessary safety precautions for protection of Supplier, its
employees, and its agents and ensuring a safe place for performance of the Services. As a material condition of this Agreement, Supplier, for itself and its employees and agents, assumes all risk of visually obvious dangers associated with the
property, and responsibility for the following OSHA notice requirements: 

  

	 	i.	informing its employees of the information provided by the AT&T Asbestos Records Contact regarding the presence, location and quantity of ACM/PACM present in the property in or adjacent to which Supplier’s
employees may reasonably be expected to work and the precautions to be taken to reasonably insure that airborne ACM/PACM is kept well below permissible exposure levels; and 


 

	 	ii.	informing the appropriate AT&T project manager and other employers of employees at the property of the presence, location and quantity of any newly discovered ACM/PACM identified by Supplier within twenty-four
(24) hours of its discovery. 

  

	 	e.	Should Services require the drilling or cutting/lifting of presumed asbestos containing/asbestos-containing flooring (e.g., floor tile or sheet rolled goods such as linoleum), Supplier agrees that its employees and
Subcontractors performing such drilling or cutting/lifting will use AT&T’s Technical Practice 76300 (section G) Procedure for Drilling or Cutting/Lifting Asbestos-Containing/Presumed Asbestos Containing Flooring (“AT&T’s
Procedure”) which has a Negative Exposure Assessment when drilling or cutting/lifting such flooring and that only employees and Subcontractors who have received the annual training required to perform AT&T’s Procedure will perform such
drilling or cutting/lifting procedures. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 71 









 Software and Professional Services Agreement 

 


	 	i.	In accordance with AT&T’s Procedure, AT&T shall either supply Supplier written documentation verifying the absence of ACM in states where asbestos disturbance is not allowed and Supplier shall proceed with
drilling or cutting/lifting when the cuts or drills will be in non-asbestos containing floors. 

  

	 	ii.	If no information regarding asbestos content of the flooring is available, in accordance with AT&T’s Procedure, the AT&T project manager will arrange for either 1) a licensed asbestos building inspector to
obtain a sample of the floor to determine asbestos content or lack thereof; or 2) a licensed asbestos abatement contractor to drill the holes or remove the asbestos-containing materials and properly dispose of the debris. 


 

	 	iii.	Supplier will not be liable for any liquidated damages related to any delay associated with AT&T’s failure or delay in providing Supplier with the information, documentation or work by a licensed asbestos
contractor pursuant to this sub-paragraph (e). 

  

	 	f.	Supplier hereby releases AT&T from any and all claims or causes of action in connection with the responsibilities assumed by Supplier in Subsections d.i, d.ii., and e. of this Section above, and agrees to indemnify,
hold harmless and defend AT&T, its Affiliates and its and their employees, agents, officers, and directors against any Loss arising therefrom or in connection therewith, in accordance with the Section of this Agreement entitled
“Indemnity.” 

  

	 	g.	If in Supplier’s judgment, the Services, other than Services requiring the drilling or cutting/lifting of asbestos-containing flooring, should not proceed due to the presence of ACM/PACM and/or any other unsafe
condition, the correction of which may require changes or alterations in AT&T’s operations or property, Supplier shall notify the AT&T project manager immediately, and shall suspend the Services until Supplier and AT&T agree on the
corrections or alterations necessary for the safe performance of the Services. Supplier will not be liable for any liquidated damages related to any delay associated with such a suspension. 


 

	4.8	Error Severity Level Description And Resolution Plan 

 The Parties agree that the use of
this Section, and/or the use of Section 4.9, Liquidated Damages for Delay in Delivery, may be applied as identified in the related Custom Software development Order. The Parties also agree that this Section 4.8, Error Severity Level
Description And Resolution Plan, may apply to OnGoing Support Orders following Warranty. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 72 









 Software and Professional Services Agreement 

 


	 	a.	During the term of the applicable Order and, if Software fails to operate in conformance with the Specifications, or if the following specified errors (“Error”) occur, Supplier agrees to respond and perform as
follows: 

  

							
	1	  	FATAL: Reported problems preventing all useful work from being done or potential data loss or corruption, or Software functionality is inoperative; inability to use has a critical impact to AT&T’s operations.	  	 •    Acknowledgment

•    Work Around, temporary fix

•    Final fix, update, or new release

•    Communications
	  	 •    [***]

•    [***]

•    [***]

•    [***]

				
	2	  	SEVERE IMPACT: Problems disable major functions required to do productive work or Software is partially inoperative and is considered as severely restrictive by AT&T.	  	 •    Acknowledgment

•    Work around, temporary fix

•    Final fix, update, or new release

•    Communications
	  	 •    [***]

•    [***]

•    [***]

•    [***]

				
	3	  	DEGRADED OPERATIONS: Reported problems disabling specific non-essential functions; Error condition is not critical to continuing operation and/or AT&T has determined a work-around
for the Error condition.	  	 •    Acknowledgment

•    Work around, temporary fix

•    Final fix, update, or new release

•    Communications
	  	 •    [***]

•    [***]

•    [***]

•    [***]

				
	4	  	MINIMAL IMPACT: Any deviation from Specifications not otherwise included in a Severity 1, 2, or 3 category.	  	 •    Acknowledgment

•    Work around, temporary fix

•    Final Fix, update, or new release

•    Communications
	  	 •    [***]

•    [***]

•    [***]

•    [***]


  

	 	b.	In the case of a FATAL or SEVERE IMPACT Error condition, Supplier shall use its best efforts to acknowledge notification of such Error condition within the time frames indicated. 


 

	 	c.	Supplier shall correct any and all Errors in the Software in accordance with Error Severity Levels specified above. In addition, at any time during the Error correction or technical support process, AT&T may invoke
the below listed escalation procedure: 

  

	 	i.	Supplier’s escalation process is to ensure that when a problem is not being resolved in a satisfactory manner, (i) both AT&T and Supplier have a common perception of the nature and criticality of the
problem, (ii) the visibility of the problem is raised within Supplier’s organization, and (iii) appropriate Supplier resources are allocated toward solving the problem. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 73 









 Software and Professional Services Agreement 

 


	 	ii.	The following escalation process may be invoked by AT&T when an Error, defect, non-conformity or technical support issue has been reported to Supplier, the Error substantially
affects AT&T’s use of the Software, and Supplier has not yet provided a patch or bypass around the Error. 

  

	 	iii.	The escalation processes can be initiated by contacting the next higher management level within Supplier’s organization. Such Supplier designate will work with AT&T’s designated contact and management to
bring a satisfactory solution to the situation. The effort will be focused on developing an action plan and coordinating whatever Supplier resources are required to meet AT&T’s needs as rapidly as possible, within the policy stated above.


  

	 	iv.	During the period of the action plan, regular status update communications will be established between AT&T’s designate and Supplier’s designate. 


 

	 	v.	If an action plan cannot be agreed to, or if the action plan fails to provide a satisfactory solution within the time frame defined in the action plan, the problem will be escalated to Supplier’s highest management
level. 

  

	 	d.	If any FATAL or SEVERE IMPACT Software Error cannot be corrected by Supplier within the indicated timeframes, Supplier shall provide [***] or a portion thereof, that the FATAL or SEVERE IMPACT Error remains unresolved
after the work around/temporary fix resolution period specified above. [***]. 

  

	 	e.	In addition, if a FATAL Error remains unresolved [***] hours after reporting thereof by AT&T, or, if a SEVERE IMPACT Error remains unresolved [***] hours after reporting by AT&T, upon AT&T’s request,
Supplier shall provide a Software engineer at AT&T’s site(s), at no additional charge, to resolve the Software Error. 

  

	 	f.	The Parties acknowledge that DEGRADED OPERATIONS and/or MINIMAL IMPACT Errors are generally less serious than FATAL or SEVERE IMPACT Errors. The Parties further acknowledge and agree that elongated resolution of such
Errors can be detrimental to AT&T’s use of the Software. Therefore, in the event that DEGRADED OPERATIONS Errors remain unresolved [***] days after AT&T’s initial report of the Error and AT&T’s notice of required
resolution to Supplier, or MINIMAL IMPACT Errors remain unresolved [***] days after AT&T’s report of the Error and AT&T’s notice of required resolution to Supplier, Supplier shall [***], for each day beyond [***] days for DEGRADED
OPERATIONS Errors and/or [***] days for MINIMAL IMPACT Errors that the Error remains unresolved. [***]. 

  

	 	g.	 Supplier shall provide AT&T with toll-free telephone hotline assistance related to operation of the Software,
including questions about individual features or suspected malfunctions. In addition, Supplier shall provide AT&T with emergency after-hours or weekend contact 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 74 









 Software and Professional Services Agreement 

 


	 	
numbers wherein support can be obtained in the event of unavailability of the Software due to a FATAL or SEVERE IMPACT Error. If a FATAL Error is reported after hours, or during the weekend,
Supplier shall begin workaround/temporary fix activities as soon as possible. 

  

	4.9	Liquidated Damages for Delay in Delivery 

 The Parties agree that the use of this
Section, and/or the use of Section 4.8 Error Severity Level Description And Resolution Plan, may be applied as identified in the related Custom Software development Order. 

Upon discovery of anything indicating a reasonable certainty that Software and/or Services will not be delivered by the scheduled Delivery
Date, Supplier shall notify AT&T and provide the estimated length of delay. The Parties shall work jointly toward resolving the delayed delivery. If the Parties reach agreement on an extended Delivery Date and Supplier fails to meet
the extended Delivery Date, then AT&T may (i) if such delay amounts to a material breach, exercise AT&T’s termination rights under the Agreement with respect to the applicable Order, (ii) [***] hereunder, and/or (iii) further
extend the Delivery Date. No payments, progress or otherwise, made by AT&T to Supplier after any scheduled Delivery Date shall constitute a waiver of Liquidated Damages. Delivery Dates shall be extended as and to the extent Supplier is
unable to meet the original Delivery Date due to causes outside of Supplier’s control. Such extension shall be proportionate to the delay caused by factors outside Supplier’s control.

Notwithstanding anything to the contrary in the Agreement, in the event of Supplier’s failure to meet a Delivery Date as defined in the
Order (as it may have been extended in accordance with the terms as set forth herein) AT&T shall be entitled to Liquidated Damages according to the following schedule: 
  

			
	 Days Late
	  	 Liquidated Damages

	 0-14
	  	$0
	 15-44
	  	10% of fees under the Order
	 45-74
	  	10% of fees under the Order
	 75+
	  	10% of fees under the Order

 The foregoing Liquidated Damages shall be calculated cumulatively and shall be capped at a total of thirty
percent (30%) of the fees under the Order. AT&T’s taking of Liquidated Damages for failure to meet a Delivery Date shall not preclude AT&T from claiming actual damages in excess of the Liquidated Damages; provided, however, that
the amount of Liquidated Damages taken by AT&T shall be deducted from any damages awarded to AT&T. Liquidated Damages taken by AT&T for failure to meet a Delivery Date shall be excluded from the limitations of liability set forth in
the Agreement. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 75 









 Software and Professional Services Agreement 

 


	4.10	Independent Contractor 

 Supplier hereby represents and warrants to AT&T that: 

 

	 	a.	Supplier is engaged in an independent business and will perform all obligations under this Agreement as an independent contractor and not as the agent or employee of AT&T; 


 

	 	b.	Supplier’s personnel performing Services shall be considered solely the employees of Supplier and not employees or agents of AT&T; 


 

	 	c.	Supplier has and retains the right to exercise full control of and supervision over the performance of the Services and full control over the employment, direction, assignment, compensation, and discharge of all
personnel performing the Services; 

  

	 	d.	Supplier is solely responsible for all matters relating to compensation and benefits for all of Supplier’s personnel who perform Services. This responsibility includes, but is not limited to, (i) timely
payment of compensation and benefits, including, but not limited to, overtime, medical, dental, and any other benefit, and (ii) all matters relating to compliance with all employer obligations to withhold employee taxes, pay employee and
employer taxes, and file payroll tax returns and information returns under local, state and federal income tax laws, unemployment compensation insurance and state disability insurance tax laws, social security and Medicare tax laws, and all other
payroll tax laws or similar laws with respect to all Supplier personnel providing Services; 

  

	 	e.	Supplier will indemnify, defend, and hold AT&T harmless from all liabilities, costs, expenses and claims related to Supplier’s failure to comply with the immediately preceding paragraph, in accordance with
Section 3.15, “Indemnity”; and 

  

	 	f.	To the extent permissible under applicable Law, Supplier shall ensure that all individuals who provide Services under this Agreement sign an “Agreement Regarding
Non-Employment Status with AT&T” in the form attached hereto as Appendix G. Individuals currently providing Services shall sign no later than [***] days following the execution of this Agreement.
Individuals who begin providing Services only in connection with new or amended Orders shall sign no later than [***] days following the date such individual commences providing Services, and shall make available an executed copy to AT&T upon
AT&T’s request. 

  

	4.11	Payment Card Industry Data Security Standards (PCI-DSS) 


To the extent Supplier processes, transmits, and/or stores credit cardholder data and/or related transaction status for or on behalf of
AT&T, Supplier must be Payment Card Industry-Data Security Standards (PCI-DSS) compliant. Upon AT&T’s request, Supplier shall promptly submit a copy of Supplier’s executed Attestation of
Compliance (AOC) to g18906@att.com. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 76 









 Software and Professional Services Agreement 

 


	4.12	Previous Services for AT&T 

 Supplier will determine whether each individual who
performs Services for AT&T has performed Work as an employee or temporary worker for AT&T, or any AT&T Affiliate, in the six (6) months preceding the individual’s proposed commencement of Work for AT&T. Supplier will provide
AT&T with written notice of any individuals who meet the foregoing criteria. AT&T may require that Supplier provide another individual to perform the Work. 
  

	4.13	Affordable Care Act 

 For purposes of the Affordable Care Act (ACA), and in particular
for purposes of Section 4980H of the Internal Revenue Code of 1986, as amended, and the regulations thereunder, with respect to each individual provided by Supplier to work on AT&T project(s) for at least thirty (30) hours per week for
at least ninety (90) days, whether consecutive or not, Supplier represents and warrants that it or one of its Subcontractors is the common law employer of such individual and shall be responsible for either providing healthcare coverage as
required by the ACA (to the extent applicable) or for paying any Section 4980H assessable payments that may be required for failure to provide to such individual: 
  

	 	a.	health care coverage, or 

  

	 	b.	(b) affordable healthcare coverage, 

 In no event will AT&T be considered to be the
common law employer of such individual for purposes of the ACA. Supplier is required to maintain for a period of ten (10) years from the effective date of the ACA Information to show compliance with the ACA notwithstanding any other provision
in this Agreement to the contrary. 
  

	4.14	Supplier’s Audited Financial Statements 

 In the event that Supplier is not a
publicly traded corporation, Supplier shall provide to AT&T (or its third party delegate), upon request and at no charge, its bona fide and unedited audited fiscal year financial statements and other financial documents as reasonably requested
by AT&T to allow an assessment of Supplier’s financial condition. If Supplier is a subsidiary of, is owned by, has a majority of its interest held by, or is controlled by an entity (e.g., a parent company) that is not a publicly traded
corporation, then Supplier shall furnish such documents for both Supplier and its owning, controlling or parent company. If Supplier is a subsidiary of, is owned by, has a majority of its interest held by, or is controlled by an entity (e.g., a
parent company) that is a publicly traded corporation, then Supplier shall furnish publicly available documents regarding its parent company. 
  

	5.0	Special Software Terms 

  

	5.1	Modifications 

 AT&T may alter, modify, add or make other changes to Custom Software
provided hereunder at its own risk and expense or contract with third parties for such modifications. AT&T shall notify such third parties of their non-disclosure obligations. The conditions and charges,
if any, for Supplier support of such modifications shall be subject to separate agreement between AT&T and Supplier. Supplier shall have no responsibility to warrant, maintain or support such modified portion of the Custom Software or any
portion of the Custom Software that is adversely affected by such modification. Title to any such addition or modification shall remain with AT&T. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 77 









 Software and Professional Services Agreement 

 


	5.2	Program Material 

  

	 	a.	At no additional cost, Supplier shall provide AT&T with the Program Material. Supplier shall provide such Program Material no later than the originally scheduled Delivery Date. 


 

	 	b.	AT&T shall have the right to reproduce all Program Material and all machine-readable forms of the Custom Software. Any such reproductions shall include any copyright or similar proprietary notices contained in the
items being reproduced. 

  

	6.0	Miscellaneous Provisions 

  

	6.1	Allowable Expenses 

  

	 	a.	AT&T is not responsible for any travel, meal or other business related expense incurred by Supplier whether or not incurred in its performance of its obligations under this Agreement, unless such expense complies
with the requirements of AT&T’s Vendor Expense Policy attached hereto and incorporated herein as Appendix H, and is not otherwise restricted under the terms of this Agreement or any applicable Order. Upon request by AT&T, Supplier shall
use commercially reasonable efforts to provide in a timely manner supporting documentation for any unusual or out of the ordinary expenses or in instances when the applicable AT&T approver cannot make a reasonable determination on the propriety
of the transaction without such documentation. The Parties further agree that for the purpose of determining when an expense is “incurred” pursuant to Section 2.1 of the Vendor Expense Policy, Supplier shall be deemed to incur such
expense when the invoice or expense voucher for such expense is submitted to Supplier’s Accounts Payable department for payment. 

  

	 	b.	Additionally, the Parties agree as follows: 

  

	 	i.	Travel and living expenses will not be paid for resources working at their primary work location or in the same metropolitan area as their primary work location. 


 

	 	ii.	Travel and living expenses for all Orders shall be limited to [***], unless agreed otherwise by the Parties in a specific Order. 

  

	6.2	Reporting 

  

	 	a.	All work whether on a time and materials or fixed bid basis will be reported in a standard billing format to be agreed upon. 

  

	 	b.	Supplier will follow reasonable time reporting practices and guidelines, as specified and/or modified by AT&T from time to time and agreed with Supplier, for all time and materials engagements and Projects. In time
and materials Projects (and not fixed price Projects), Supplier shall describe hours worked reported by personnel level; new development versus maintenance; domestic/offshore hours by release item; and employee, the hours worked and time incurred.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 78 









 Software and Professional Services Agreement 

 


	 	c.	For all AT&T Technology Development time and materials Orders, Supplier resources will report time in AT&T’s Cost Management Project Management (CMPM) application, or the then-current time reporting system,
by[***] and all hours shall be reported by the [***] before the CMPM application closes. AT&T will provide PMT codes for all assigned/requested work to allow for Amdocs resources to charge their time accordingly. In the event that a PMT is not
available or has not been provided, AT&T will provide an alternative PMT to use until the correct PMT can be identified at which point the hours will be moved over from the alternative to the correct PMT. 


 

	6.3	Disaster Recovery and Business Continuity Plan: 

  

	 	a.	Supplier will provide a Disaster Recovery and Business Continuity Plan at all times during the term of this Agreement for their offshore operations associated with each Project and or Application that is assigned to
them by AT&T as set forth in Appendix J, “Disaster Recovery and Business Continuity Plan”. Such Disaster Recovery and Business Continuity Plan shall be reviewed and agreed upon with AT&T. 


 

	 	b.	This should include, but not be limited to: 

  

	 	i.	Demonstrate the existence of a recovery strategy, which is complimentary to AT&T that is exercised with documented conclusions and recommended improvements. 


 

	 	ii.	Ensure that failover processes and procedures are in place to support AT&T applications and these failover processes and procedures are exercised annually (at a minimum). 


 

	 	iii.	Ensure that adequate communication documents, processes, and procedures are readily available and kept up to date. 

  

	6.4	Clauses Applicable to Call Center Work 

 In the event an Order involves Call Center Work,
the following clauses shall apply. 
  

	 	a.	AT&T Clean Desk Policy 

 AT&T data, records, and customer information must
always be protected from unauthorized access, use or disclosure. Additional protections or exceptions mandated by unique circumstances with appropriate approvals may be added to this Standard Policy by mutual agreement of the Parties per individual
order. 
 Supplier shall take all necessary steps to ensure that no Supplier person who has access to AT&T data, records, or information
regarding any AT&T customer (“Agent”) has the ability to record any AT&T customer information either via written, electronic or any other instrumentation. Accordingly, in all areas where AT&T data, records or information
regarding AT&T customers is accessible or viewable, Suppliers must ensure the following: 
  

	 	i.	Supplier shall ensure that all Agents are prevented access to any writing instruments or paper of any kind, within reason. 

  

	 	ii.	Electronic devices that may be used to record video, take photographs or otherwise communicate information (examples include but are not limited to, mobile phones, blue tooth devices,
e-Readers, gaming devices, wearable electronics, personal tablets or laptops) are prohibited. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 79 









 Software and Professional Services Agreement 

 


	 	iii.	Notes displaying sensitive information such as user ID’s, passwords, customer account numbers, or other sensitive personal information of AT&T customers is strictly prohibited.    AT&T
customer information must NEVER be written down, typed, recorded (voice or image) or transmitted.    These prohibitions notwithstanding, Agents may type customer information into authorized AT&T systems only where it is
required; and Supplier shall record and retain customer calls and screen shots as required in accordance with the MSA and its Orders. 

  

	 	iv.	Supplier shall disable all external storage ports (CDROM, DVD, or USB drives) from all Agents’ desktop or laptop computers that are used to access AT&T systems or data. 


 

	 	v.	For all desktop, laptop or tablet computers that are used by Agents to access AT&T systems or data, Supplier shall block access to all internet sites except those approved for use by
AT&T.    Additionally, access to any websites that allow for webmail, file sharing, data storage, or online notepad capabilities (examples: gmail, yahoo mail, dropbox, one drive, etc.) is prohibited on any desktop or laptop
computer that is used by Agents to access AT&T systems or data. 

 Additionally, the following procedures must also be in
place: 
  

	 	i.	Clear fax machines, printers and copiers of any AT&T data, records or customer information immediately 

  

	 	ii.	Agents shall lock desktop and /laptop computers when leaving their station for any period of time 

  

	 	iii.	Laptops and tablets that allow for access to AT&T data, records, or customer information must be physically secured in place and may not be removed from the Supplier location 


 

	 	iv.	Supplier shall physically secure any area where AT&T data, records or customer information is accessible to prevent access by unauthorized persons. 


Supplier shall perform routine inspections to be completed no less than [***] to ensure adherence to these processes. If any inspection shows non-compliance with the processes as outlined herein, Supplier shall promptly take all actions necessary to immediately comply and shall bear the cost thereof. 

AT&T Clean Desk Audits may be conducted as needed and at AT&T’s sole discretion without advance notice.    

  

	 	b.	Customer Protection Policy 

  

	 	i.	In addition to the reporting and notification requirements contained elsewhere in this Agreement, Supplier also agrees to take all appropriate steps to prevent and respond to these specific type of Incidents involving
the mistreatment of AT&T’s customers. To protect AT&T’s customers, as well as AT&T, its Affiliates and its services, from the effects of such mistreatment, Supplier will not permit any of its Customer Service Representatives
(CSRs) or other employees (e.g., trainers, supervisors) to engage in any of the following actions: 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 80 









 Software and Professional Services Agreement 

 


	 	1.	Using vulgar, offensive, abusive, or sexually oriented language in communications with Customers. 

  

	 	2.	Making derogatory references to race, color, religion, national origin, sex, age, sexual orientation, marital status, veteran’s status or disability in communications with Customers. 


 

	 	3.	Yelling or screaming, making rude, argumentative, abrasive, or sarcastic comments in communications with Customers. 

  

	 	4.	Flirting or making social engagements with Customers or AT&T representatives, including the exchange of personal email addresses. 


 

	 	5.	Intentional acts of call avoidance, including but not limited to: 

  

	 	A)	Intentional disconnect of a Customer during a call. 

  

	 	B)	Intentional transfer of a call back into the queue that the CSR is trained to handle. 

  

	 	C)	Intentional dissemination of inaccurate information or troubleshooting steps in order to release a call without assisting the Customer. 


 

	 	D)	Intentionally ignoring a Customer that has been presented to the CSR from a call queue. 

  

	 	6.	Intentionally abandoning a Customer on hold for an excessive period of time without providing a status update to the Customer. 

  

	 	7.	Refusing to escalate to a supervisor at the Customer’s request. 

  

	 	8.	Refusing to assist Customers with requests that the CSR is trained to handle. 

  

	 	9.	Any unauthorized access, release or use of confidential information, such as Customer account information. This shall include, but not be limited to, accessing a Customer’s email account without permission and/or
creating a password for a Customer without authorization. 

  

	 	10.	Retaining, collecting, accessing, and/or using Customer information for reasons outside the scope of support of an Order. 

  

	 	11.	Any attempt to falsify AT&T’s records or any record related to a Customer. 

  

	 	12.	Any statements that intentionally misrepresent, or provide misleading information about, AT&T or its products, pricing or promotions. 


 

	 	13.	Any intentional or reckless acts that create a risk of compromising the privacy of customer information, including failure to strictly comply with the “Clean Desk Policy,” as defined herein and in Appendix D,
which requires that AT&T Information be secured any time a CSR goes on a break or is away from the CSR’s work area. 

  

	 	ii.	 Supplier shall submit a [***] report to AT&T’s Vendor Manager identifying any instances where any of the
prohibited conduct listed in Subsection a, of this Section occurred at a Supplier facility during the preceding month. Supplier shall deliver the report to AT&T’s Vendor Manager on the [***], or on the next business day if the [***] day is
a weekend or holiday. This report shall include: (i) the name of the facility where 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 81 









 Software and Professional Services Agreement 

 


	 	
the Incident occurred; (ii) the date of the Incident; (iii) a brief description of the Incident; and (iv) a brief description of the action taken by Supplier to address the
Incident. Supplier shall not identify individual CSRs by name or identification number in such reports. 

  

	 	iii.	Supplier and AT&T agree that violations of this Customer Protection Policy will injure AT&T’s relationships with its Customers and that the amount of such injury may be difficult to quantify. As a remedy
for any such injury, Supplier and AT&T agree that in the event that a Supplier CSR or other employee violates any of the above provisions of this Customer Protection Policy, Supplier shall pay to AT&T liquidated damages in the amount of
[***] for each such violation. A violation is one provision one time. Multiple violations are those violations of the same provision more than once or of multiple provisions one or more times. AT&T will be entitled to collect this [***] under
this Agreement.    Such liquidated damages are not a penalty but rather represent a reasonable estimate of the damages that would occur from Supplier’s breach of the foregoing obligation. 


 

	 	iv.	In order to protect its customers from further mistreatment in circumstances involving any of the behaviors that fall within the scope of Subsection b.i. of this Section, AT&T may request that Supplier immediately
remove a CSR or any other employee of Supplier (e.g. trainers, supervisors) from all AT&T Programs. 

  

	 	v.	Supplier shall be wholly responsible for accepting or rejecting a request to remove pursuant to Subsection b.iv. of this Section and for any other remedial measures related to the CSR or other employee of Supplier.
[***]. 

  

	7.0	Relationship Management 

  

	7.1	Relationship Management 

  

	 	a.	The Parties shall approach the relationship with Supplier performing the Services in a close working relationship with AT&T Technology Development, subject to Section 4.10, “Independent Contractor”,
of this Agreement. Supplier will bring its expertise, knowledge and technology solutions to AT&T Technology Development executive leadership, and shall work in concert with the AT&T Technology Development organization in bringing solutions
to AT&T business units. 

  

	 	b.	Supplier will reasonably endeavor to solicit the active participation by AT&T Global Supply Chain and AT&T Technology Development representation, prior to presentation of Technology Development-related solutions
to the AT&T Business Unit, and Supplier will reasonably endeavor to include the AT&T Global Supply Chain and AT&T Technology Development representatives where appropriate in meetings with AT&T business units. 


 

	7.2	Proposed Projects 

  

	 	a.	 Whenever AT&T is considering contracting with Supplier for a proposed Project, AT&T’s and
Supplier’s Leadership representatives shall make reasonable efforts to meet or otherwise discuss the project. A draft describing the requirement of Software and the functionality required for such proposed Project may be prepared and submitted
by AT&T to Supplier. 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 82 









 Software and Professional Services Agreement 

 


	 	
Such description may include the name of the proposed Project, the name, address and telephone number of AT&T’s Project Manager, any special time requirements for the proposed Project,
the platform on which the Software is to operate and the programming language desired, any methods or criteria for testing the Software (in addition to or different from those specified elsewhere in this Agreement), and any other conditions which
are significant to AT&T in considering the assignment of such Project. 

  

	 	b.	Upon reasonable time to review the requirements, Supplier shall notify AT&T as to whether Supplier will submit to AT&T a Proposal Statement for the proposed Project. If Supplier elects to submit a Proposal
Statement, it shall include, but not be limited to, each of the following items whenever such item is applicable to the Project: 

  

	 	i.	Supplier’s interpretation of the initial scope of the functional specifications based on Supplier’s knowledge of AT&T’s technology direction, hardware, and software standards for such Project, and any
Standard Software which will be used as a part of the Software, if applicable; 

  

	 	ii.	Supplier’s license fees, and maintenance support fees, for any Standard Software which may be included in the Software, if applicable; 


 

	 	iii.	Supplier’s estimate of the costs for the development of the Custom Software. Such estimate shall be in sufficient detail that AT&T may readily determine the costs applicable to the computer environment,
Services, labor time and Material. Such estimate shall provide either (i) a fixed fee, or (ii) an express statement that Supplier proposes to accomplish the development work on a time and charges basis; and 


 

	 	iv.	The anticipated Delivery Date for the Software. 

  

	 	c.	Such proposals shall include a breakdown of the estimated hours and expenses, where applicable. Estimates are provided based upon then-current information, and factors arising during the preparation of the Order may
necessitate proposed changes in resource estimates and/or expenses. 

  

	 	d.	Each such Proposal Statement shall be subject to AT&T’s written acceptance, and any such Proposal Statement may be modified as agreed by the Parties prior to placing an Order for Services. 


 

	 	e.	Within a reasonable time after receiving Supplier’s written Proposal Statement covering any proposed Project, AT&T shall notify Supplier in writing of AT&T’s acceptance or rejection of such Proposal
Statement. AT&T shall also identify any requirements that have not already been addressed by Supplier in the Proposal Statement. 

  

	 	f.	If the Proposal Statement is accepted, the Parties shall prepare an Order for Software and/or Services substantially similar to Appendices XX or YY, as applicable. Unless otherwise agreed in the Order, AT&T shall
incur no obligation, cost, or expense as a result of Supplier’s preparation of a Proposal Statement or AT&T’s rejection of same. Supplier shall have no Liability in connection with (i) a Proposal Statement; (ii) an Order
unless executed by both Parties; or (iii) rejection of a draft Order. 

  

	 	g.	AT&T shall have no obligation under this Agreement to compensate Supplier for any Services rendered absent the execution of an Order. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 83 









 Software and Professional Services Agreement 

 


	 	h.	When such an Order is executed by AT&T and Supplier, Supplier shall proceed to develop such Custom Software or provide the applicable Services, in compliance with the Specifications contained within such Order.


  

	7.3	Project Management 

  

	 	a.	Supplier and AT&T shall each designate a Project Manager, and shall identify those individuals on the Order. The Project Managers shall act as the primary interface between the Parties during the development of
Software and Delivery of Services by Supplier. The Parties’ respective Project Managers shall be responsible for ensuring the continuity of communications between the Parties as the Project proceeds. 


 

	 	b.	On a periodic basis during the development of Software, the Parties shall meet for Supplier to inform AT&T of the Project status. Such meetings shall include each Party’s Project Manager as well as appropriate
additional personnel, and where appropriate upon request, Supplier shall provide AT&T at each such meeting with a written status report on the work being performed by Supplier. Alternatively, the Parties may elect to forego all, or some, of such
meetings and may agree that Supplier may simply provide AT&T with periodic written reports on the status of the projects being undertaken by Supplier under this Agreement and related Orders, including appropriate financial information. The
frequency of meetings and status reports shall be determined by the Project Managers. 

  

	 	c.	AT&T may inspect any work and all related data and Documentation being performed by Supplier, including work being performed at Supplier’s premises, upon reasonable prior notice. AT&T shall conduct any such
inspection in a manner which causes no delay or material disruption to the performance of the Project. 

  

	 	d.	A Party shall notify the other in a timely fashion of any anticipated, or known, delay in the performance of any of its responsibilities and shall include all relevant information concerning the delay, or potential
delay. Any delay by AT&T shall increase any dependent Supplier deadline or milestone by a period at least equal to the amount of the AT&T delay. In such event the Parties will employ the agreed change management protocols to document the
resultant changes to the Project Plan and anticipated fees and expenses. 

  

	 	e.	Any Project change, which reflects a material change in price or schedule, must so specifically state in writing and be approved by both Parties in writing before a change is implemented by a Party. For avoidance of
doubt, the changes agreed upon in writing between the Parties will be memorialized as an amendment to the applicable Order under which there is a material change to the Project. 


 

	 	f.	In the event there is a dispute that will materially impact a Project that is not resolved by the Parties’ Project Managers, each Party shall be entitled to submit notice of the dispute to the other Party in
writing, described in complete detail, and signed by an authorized representative of the disputing Party. Within fifteen (15) days after a Party receives a written description of the dispute, a meeting shall be conducted between the Parties’
respective account managers to resolve the dispute. If the dispute is not resolved within fifteen (15) days after the initial dispute resolution meeting, the dispute shall be escalated to the higher management levels of the respective organizations.
If the issue is not resolved within thirty (30) days following the meeting at the management levels, the dispute may be escalated to executive leadership defined in Section 4.5, “Dispute Resolution”. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 84 









 Software and Professional Services Agreement 

 


	 	g.	If AT&T, within [***] days after commencement of work by an individual provided by Supplier, determines, in its sole discretion, that the individual does not demonstrate the training or the skills to perform the
services in a satisfactory fashion or is not performing the services in a professional, effective and efficient manner, the Parties’ Project Managers will attempt to resolve the matter within [***] days. If the Parties [***], Supplier shall
[***]. In addition to the above remedies, if any Supplier OnGoing Support personnel are not performing to AT&T’s reasonable satisfaction, the Parties shall attempt to resolve the problem within [***] days after the date on which AT&T
escalates the matter to Supplier’s Project Manager. [***] shall be [***]. 

  

	 	h.	In the event that Supplier subcontracts all or a portion of the Project to a Subcontractor the following will apply. Supplier shall notify AT&T in advance of utilizing a Subcontractor in accordance with
Section 3.44, “Work Done By Others”, and such Subcontractors shall be identified by company name and work location on the Order. AT&T reserves the right to reasonably review and approve any or all Subcontractors used. Where
required under the terms of the applicable Order, Supplier shall be responsible for all Acceptance testing including unit, chain, stress and end-to-end production
validation as part of the Delivery of the Subcontractor’s Material and/or Services to Supplier and Supplier shall review and/or audit the activities and work product(s) of the Subcontractor for managing the Software subcontract and reporting
results to AT&T, in accordance with the Order. Notwithstanding the foregoing, Supplier will not be required to identify to AT&T the name of a Subcontractor that is an Affiliate of Supplier, provided that Supplier will be responsible for
performance by such Subcontractor as specified in this Section. 

  

	 	i.	Knowledge transfer to the AT&T-named team is to be included as a part of every Project to the extent and in the manner specified in the applicable Order. This may include, but
is not be limited to, design walkthroughs, detailed design reviews, test result walkthroughs, processing and job flow review, operational and architectural review, environment review and any other reasonable request at AT&T’s sole
discretion, and the appropriate documentation as provided by Supplier. 

  

	 	j.	If required by AT&T and specified in the Order, Supplier shall supply Project-related personnel for a post-termination transition period during which Supplier’s personnel remain on site, or available for
consultation. The fees shall be no more than Supplier’s then-current standard rates, and the time frame for such a transition period shall be determined by AT&T and specified in the Order. 


 

	7.4	Hardware and Third Party Software Considerations 

  

	 	a.	AT&T does not accept bundled Hardware and Software costs. Where a solution is proposed containing Hardware resale from Supplier, Supplier shall breakout the Hardware component. 


 

	 	b.	All Hardware and Third Party Software acquisitions by AT&T through Supplier should either align with AT&T’s corporate standards and strategic direction or be supported by an authorized Technology Strategies
and Standards (“TSS”) exception, in either case as determined by AT&T and as such determination is communicated to Supplier. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 85 









 Software and Professional Services Agreement 

 


	 	c.	All Hardware and Third Party Software purchases by AT&T through Supplier will be managed through its defined acquisition process. 


 

	 	d.	Except as otherwise agreed and provided in the Order, the terms and conditions governing the supply, warranty and maintenance, and other aspects of Hardware and Third Party Software purchases by AT&T through
Supplier will be the terms and conditions offered by the relevant manufacturer(s) or vendor(s). 

  

	 	e.	Supplier has, from time to time, reseller agreements with manufacturers and/or vendors of Hardware and Third Party Software. AT&T may allow Supplier to submit bids to AT&T to purchase such components through
Supplier. 

  

	8.0	Execution of Agreement 

  

	8.1	Transmission of Original Signatures and Executing Multiple Counterparts 

 Original
signatures transmitted and received via facsimile or other electronic transmission of a scanned document (e.g., pdf or similar format) are true and valid signatures for all purposes hereunder and shall bind the Parties to the same extent as that of
original signatures. This Agreement may be executed in multiple counterparts, each of which shall be deemed to constitute an original but all of which together shall constitute only one document. 

THIS AGREEMENT CONTAINS A BINDING ARBITRATION 

PROCEDURE WHICH MAY BE ENFORCED BY THE PARTIES. 

IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed as of the Effective Date. 

 

							
	 Amdocs, Inc. 
	  	AT&T Services, Inc.
				
	By:	 	 /s/ Michael Saeger
	  	By:	  	 /s/ Deidre D. Byer

				
	Name:	 	Michael Saeger	  	Name:	  	Deidre D. Byer
				
	Title:	 	President and Secretary	  	Title:	  	 Sr. Sourcing Manager,
 Global Supply
Chain

				
	Date:	 	2/28/2017	  	Date:	  	2/28/2017


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 86 









 Software and Professional Services Agreement 

 

 APPENDICES 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 87 









 Software and Professional Services Agreement 

 

 Appendix A – Supplier’s Price(s) 

Supplier shall provide Services, if any, including any applicable deliverables, for the prices defined within this Appendix A. 

 

	A.	Job Classification Descriptions 

 Senior Project Manager/Senior Team Lead:
[***] or more years’ experience in information technology with at least [***] in a Project Manager or Team Lead role. Proven ability to manage and lead projects of a large scale. Project Management Certification or Degree. Leadership and
communication skills. 
 Project Manager/Team Leader: [***] or more years’ experience in information technology with at
least [***]in a Project Manager or Team Lead role. Supplier Certified as a specialist in at least two applications or systems areas relevant to the project. Demonstrated leadership experience, and solid communication skills; able to work
independently and manage other employees. 
 Senior Developer /Analyst: [***] or more years’ programming or equivalent
technical experience; good communication skills; application design experience. Supplier Certified as a specialist in at least one application or system relevant to the project. Ability to create clear, concise and detailed design documents. 

Developer/Analyst: [***] or more years’ experience, program design and development experience; knowledge of applications or
systems relevant to the project; ability to write documentation and conduct unit and system level tests. 
 Entry Level
Developer: Entry Level, typically with a university degree or equivalent qualifications, with one year or less programming experience, knowledgeable of structured programming and computer science principles require to meet the needs of
AT&T. 
 Senior System Architect: The Senior System Architect is responsible for the same activities as the Technical
Architect but has a broader scope of responsibilities and more in-depth business and technical knowledge. Responsible for multiple projects or large complex projects with cross-functional teams and business
processes. Demonstrate expert knowledge in multiple technical and business functional areas as well as performing a larger leadership role in the organization. Apply broad in-depth business and technical
knowledge to establish technical direction and priorities. Resolve and work on issues across multiple functional areas. Effectively monitor and take action to ensure coordination and effectiveness of all components and activities and decide on
issues requiring escalation. Incumbents understand the system flow for a project throughout an entire functional area (e.g., Billing, Customer Care) not just a subsystem area. They have medium to long range planning responsibilities. 

System Architect: Responsible for providing technical system solutions and determining overall design direction. Provide
technical leadership and are responsible for the technical integrity within a subsystem or application. Also provide technical expertise to generate maintainable, quality 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 88 









 Software and Professional Services Agreement 

 

 
solutions. Includes documenting system requirements, creating application designs, validating high level designs to ensure accuracy and completeness against the business requirements and
programming the solutions. Attend project meetings when technical advice is needed and communicate the project design to other architects. May resolve design issues and develop strategies to make ongoing improvements that support system flexibility
and performance. Assess the technical feasibility of new technologies to enable integration into existing processes. 
 Senior Data
Base Administrator: Responsible for high level database administration and related tasks on multiple DMBS platforms. Participates in the evaluation, selection and implementation of appropriate DBMS based on client requirements. May create
logical model and transform logical design into efficient physical databases, performing data normalization/denormalization, and considering volume, capacity and requirements for performance, data conversion, purge/archive and operation viability.
Responsible for implementing database architecture strategies. Manage database administration projects that may span across parts of the enterprise and ensure that deliverables are completed on time. Strives to drive overall costs lower for database
performance, data conversion, and administration services. Acts as consultant to clients and other IT organizations on database-related issues. Leads efforts to implement standards across the enterprise for ease of support and recovery in relation
to database administration (database security, disaster recovery, scripts, and database documentation). Evaluates and deploys new technology to improve database efficiency and recoverability. Performs advanced problem determination and recoveries.
Mentors Database Administrators and Associate Analysts. 
 Database Administrator: Responsible for database administration and
related tasks on one or more DMBS platforms. Under the guidance of the Sr. DBA, may create logical model and transform logical design into efficient physical databases, performing data normalization/denormalization, and considering volume, capacity
and requirements for performance, data conversion, purge/archive and operation viability. Responsible for meeting assigned deliverables. Responsible for assisting in driving overall costs lower for database performance, data conversion, and
administration services. Works with clients and other IT organizations to ensure positive impact. May consult with clients on database admin-related issues and design considerations. Implements standards across the enterprise for ease of support and
recovery in relation to database administration (database security, disaster recovery, scripts, and database documentation standards). 
  

	B.	Rates 

  

	 	i.	All rates defined below are based on a fixed price monthly amount of [***], and are applicable to new Work Orders, additions of scope to existing Work Orders, and extensions of existing Work Orders executed
between the Parties against this Agreement after the Effective Date of the Letter of Agreement No. 20150505.066.C. 

  

	 	ii.	Consulting Services 

 The fixed price for Consulting Services is a [***] of [***]. 

 

	 	iii.	Non-Consulting and Requirements Services 

 The
fixed price for Non-Consulting and Requirements Services is a [***] of [***]. 
  

	 	iv.	Production Support Services 

 The fixed price for Production Support Services is a [***]
of [***]. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 89 









 Software and Professional Services Agreement 

 


	 	v.	Development Services 

 The fixed price for Development Services is a [***] of [***].

  

	 	vi.	Testing Services 

 The fixed price for Testing Services is a [***] of [***]. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 90 









 Software and Professional Services Agreement 

 

 Appendix B – Forms of Order 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 91 









 Software and Professional Services Agreement 

 

 Appendix B, Exhibit 1 – For Orders requiring signature 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 92 









 Software and Professional Services Agreement 

 

 Order 

No. 53258.W.<XXX> 
 Between

 Amdocs, Inc. 
 And 

AT&T Services, Inc. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 93 









 Software and Professional Services Agreement 

 

 Order 

This Order is by and between Amdocs, Inc., a Delaware corporation (“Supplier” or “Amdocs”), and AT&T Services, Inc., a Delaware
corporation (“AT&T”), and shall be governed pursuant to the terms and conditions of Master Services Agreement Number 53258.C (the “Master Services Agreement”), which by this reference are incorporated as if fully set forth
herein. Any terms and conditions in this Order that vary from or are inconsistent with the terms and conditions of the Software Master Agreement Number 24340.C, formerly 03032360, (the “Software Master Agreement”) or the Master Services
Agreement shall apply to this Order only, and shall survive the termination or expiration of the Master Services Agreement or the Software Master Agreement. 
  

	1.	AT&T Agreement Number: 53258.W.<XXX> must appear on all invoices 

 Amdocs
Order Number: <Enter No.> 
  

	2.	Term of Services: Effective dates are <Month, DD, YYYY>, through <Month, DD, YYYY>. 

  

	3.	Project Name and Description: <Enter Details> 

  

	4.	The Custom Software and Program Material and/or Scope of Other Services Ordered: 

 This
Order is to <Enter specific details> 
  

	5.	Third Party Software: <Enter here if any; “None” is acceptable> 

  

	6.	Additional Items Ordered: <Enter here if any; “None” is acceptable> 

  

	7.	Milestones/Resources: 

  

	 	a.	Milestones: 

 Planned milestones as of the Effective Date of this Order are as follows:

 <Table below is an example and may be modified as required> 

 

					
	 Milestone No.
	  	 Description
	  	 Date

	 1
	  		  	

  

	 	b.	Offshore Resources: 

 Amdocs Offshore resources working on this Order may be located at AT&T-approved locations found in the Master Services Agreement, and at the following address(es): 

<Address Number Street and Room> 

<City, State/Province Zip> 

<Country> 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 94 









 Software and Professional Services Agreement 

 

 Amdocs Offshore resources can only access AT&T Systems/data in accordance with the
Master Services Agreement, Appendix D, “Security and Offshore Requirements”. 
  

	 	c.	USA-Based Resources: 

 Amdocs USA-based resources shall work pursuant to the general directions provided by AT&T to Amdocs towards the assigned milestones but shall not in any way be deemed to be employees of AT&T. 

 

	 	d.	Staffing Details: 

 Planned roles and full time equivalent (“FTE”) resources
needed: 
 <Table below is an example and may be modified as required> 

 

							
	 Role
	  	 USA-Based
FTEs
	  	 Offshore FTEs
	  	 Total



 

	8.	Deliverables/Release Items: 

 Amdocs will provide the deliverables and/or release items
for the Project as defined in this Section and the table below. 
 <Table below is an example and may be modified as required> 

 

							
	 Milestone No.
	  	 Deliverable
	  	 Description
	  	 Estimated Delivery Date



 

	9.	Application Components: <Enter details below, “None” is acceptable and delete table> 


The following applications are included in the scope of this Order. 
  

					
	 MOTS ID
	  	 Application Name
	  	 % of time spent on Application

	 Total
	  		  	100%

  

	10.	Amdocs Responsibilities: <Enter details below, “None” is acceptable>  


In addition to providing the deliverables herein, Amdocs will be responsible for the following: 

 

	 	•	 	<List additional Amdocs Responsibilities> 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 95 









 Software and Professional Services Agreement 

 


	11.	AT&T Responsibilities: <Enter details below, “None” is acceptable> 


In addition to AT&T Responsibilities defined in Section 3.43f of the Master Services Agreement, AT&T will be responsible for the
following: 
  

	 	•	 	<List additional AT&T Responsibilities> 

  

	12.	Compensation: 

 This is a <fixed price or Time and Materials (“T&M”)>
Order for the total amount of <Enter amount> for the Work effort. The total price is based on <Enter basis for pricing, e.g. rate, monthly or hourly, any proration, and/or assumed hours>. 

<Enter Travel and living expenses language in accordance with the Master Services Agreement, if applicable> 

The following table represents the payment schedule for this Order: 

Payment Schedule: 

<Table below is an example and may be modified as required> 
  

									
	 Activity

During
	  	 FTEs
	  	 Rate
	  	 Total Invoice
	  	 Invoice Date

	 Total
	  		  		  		  	

  

	13.	Project Managers: 

 AT&T: 

<AT&T Contact Name> 

<Title> 
 <Street and
Room> 
 <City, State Zip> 

<email@att.com> 

Amdocs:     

<Amdocs PM Contact Name> 

<Title> 
 <Street and
Room> 
 <City, State Zip> 

<email@amdocs.com> 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 96 









 Software and Professional Services Agreement 

 


	14.	Liquidated Damages for Delay in Delivery And/Or Error Severity Level Description And Resolution Plan 


<Note: the following paragraph contains the instructions and agreed upon general use of this section between the Parties. Which
clause to use will be dependent on the Project.> 
 The Parties agree that applying Liquidated Damages for Delay in Delivery and/or the
Error Severity Level Description And Resolution Plan may be applied based on the Custom Software development Services provided in the Order. The Parties also agree that the Error Severity Level Description And Resolution Plan may apply to OnGoing
Support Orders following Warranty. 
  

	 	a.	Liquidated Damages for Delay in Delivery 

 Upon discovery of anything indicating a
reasonable certainty that Software and/or Services will not be delivered by the scheduled Delivery Date, Supplier shall notify AT&T and provide the estimated length of delay. The Parties shall work jointly toward resolving the delayed
delivery. If the Parties reach agreement on an extended Delivery Date and Supplier fails to meet the extended Delivery Date, then AT&T may (i) if such delay amounts to a material breach, exercise AT&T’s termination rights
under the Master Services Agreement with respect to the applicable Order, (ii) exercise its right to recover Liquidated Damages specified hereunder, and/or (iii) further extend the Delivery Date. No payments, progress or otherwise,
made by AT&T to Supplier after any scheduled Delivery Date shall constitute a waiver of Liquidated Damages. Delivery Dates shall be extended as and to the extent Supplier is unable to meet the original Delivery Date due to causes outside of
Supplier’s control. Such extension shall be proportionate to the delay caused by factors outside Supplier’s control.

Notwithstanding anything to the contrary in the Master Services Agreement, in the event of Supplier’s failure to meet a Delivery Date as
defined in the Order (as it may have been extended in accordance with the terms as set forth herein) AT&T shall be entitled to Liquidated Damages according to the following schedule: 

 

			
	 Days Late
	  	 Liquidated Damages

	0-14	  	$0
	15-44	  	10% of fees under the Order
	45-74	  	10% of fees under the Order
	75+	  	10% of fees under the Order

 The foregoing Liquidated Damages shall be calculated cumulatively and shall be capped at a total of thirty
percent (30%) of the fees under the Order. AT&T’s taking of Liquidated Damages for failure to meet a Delivery Date shall not preclude AT&T from claiming actual damages in 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 97 









 Software and Professional Services Agreement 

 

 
excess of the Liquidated Damages; provided, however, that the amount of Liquidated Damages taken by AT&T shall be deducted from any damages awarded to AT&T. Liquidated Damages taken
by AT&T for failure to meet a Delivery Date shall be excluded from the limitations of liability set forth in the Master Services Agreement 
  

	 	b.	Error Severity Level Description And Resolution Plan 

  

	 	i.	During the term of the applicable Order and, if Software fails to operate in conformance with the Specifications, or if the following specified errors (“Error”) occur, Supplier agrees to respond and perform as
follows: 

  

							
	1        	  	FATAL: Reported problems preventing all useful work from being done or potential data loss or corruption, or Software functionality is inoperative; inability to use has a critical impact to AT&T’s operations.	  	 •           Acknowledgment

•           Work Around, temporary fix

•           Final fix, update, or new release

•           Communications
	  	•           [***]

•           [***]

•           [***]

•           [***]

				
	2	  	SEVERE IMPACT: Problems disable major functions required to do productive work or Software is partially inoperative and is considered as severely restrictive by AT&T.	  	 •           Acknowledgment

•           Work around, temporary fix

•           Final fix, update, or new release

•           Communications
	  	•           [***]

•           [***]

•           [***]

•           [***]

				
	3	  	DEGRADED OPERATIONS: Reported problems disabling specific non-essential functions; Error condition is not critical to continuing operation and/or AT&T has determined a work-around
for the Error condition.	  	 •           Acknowledgment

•           Work around, temporary fix

•           Final fix, update, or new release

•           Communications
	  	•           [***]

•           [***]

•           [***]

•           [***]

				
	4	  	MINIMAL IMPACT: Any deviation from Specifications not otherwise included in a Severity 1, 2, or 3 category.	  	 •           Acknowledgment

•           Work around, temporary fix

•           Final Fix, update, or new release

•           Communications
	  	•           [***]

•           [***]

•           [***]

•           [***]


  

	 	ii.	In the case of a FATAL or SEVERE IMPACT Error condition, Supplier shall use its best efforts to acknowledge notification of such Error condition within the time frames indicated. 


 

	 	iii.	Supplier shall correct any and all Errors in the Software in accordance with Error Severity Levels specified above. In addition, at any time during the Error correction or technical support process, AT&T may invoke
the below listed escalation procedure: 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 98 









 Software and Professional Services Agreement 

 


	 	A.	Supplier’s escalation process is to ensure that when a problem is not being resolved in a satisfactory manner, (i) both AT&T and Supplier have a common perception of the nature and criticality of the
problem, (ii) the visibility of the problem is raised within Supplier’s organization, and (iii) appropriate Supplier resources are allocated toward solving the problem. 


 

	 	B.	The following escalation process may be invoked by AT&T when an Error, defect, non-conformity or technical support issue has been reported to Supplier, the Error substantially
affects AT&T’s use of the Software, and Supplier has not yet provided a patch or bypass around the Error. 

  

	 	C.	The escalation processes can be initiated by contacting the next higher management level within Supplier’s organization. Such Supplier designate will work with AT&T’s designated contact and management to
bring a satisfactory solution to the situation. The effort will be focused on developing an action plan and coordinating whatever Supplier resources are required to meet AT&T’s needs as rapidly as possible, within the policy stated above.


  

	 	D.	During the period of the action plan, regular status update communications will be established between AT&T’s designate and Supplier’s designate. 


 

	 	E.	If an action plan cannot be agreed to, or if the action plan fails to provide a satisfactory solution within the time frame defined in the action plan, the problem will be escalated to Supplier’s highest management
level. 

  

	 	iv.	If any FATAL or SEVERE IMPACT Software Error cannot be corrected by Supplier within the indicated timeframes, Supplier shall provide [***] or a portion thereof, that the FATAL or SEVERE IMPACT Error remains unresolved
after the work around/temporary fix resolution period specified above. [***]. 

  

	 	v.	In addition, if a FATAL Error remains unresolved [***] after reporting thereof by AT&T, or, if a SEVERE IMPACT Error remains unresolved [***] after reporting by AT&T, upon AT&T’s request, Supplier shall
provide a Software engineer at AT&T’s site(s), at no additional charge, to resolve the Software Error. 

  

	 	vi.	The Parties acknowledge that DEGRADED OPERATIONS and/or MINIMAL IMPACT Errors are generally less serious than FATAL or SEVERE IMPACT Errors. The Parties further acknowledge and agree that elongated resolution of such
Errors can be detrimental to AT&T’s use of the Software. Therefore, in the event that DEGRADED OPERATIONS Errors remain unresolved [***] after AT&T’s initial report of the Error and AT&T’s notice of required resolution to
Supplier, or MINIMAL IMPACT Errors remain unresolved [***] after AT&T’s report of the Error and AT&T’s notice of required resolution to Supplier, Supplier shall issue [***], for each day beyond [***]for DEGRADED OPERATIONS Errors
and/or [***] days for MINIMAL IMPACT Errors that the Error remains unresolved. [***]. 

  

	 	vii.	Supplier shall provide AT&T with toll-free telephone hotline assistance related to operation of the Software, including questions about individual features or suspected malfunctions. In addition, Supplier shall
provide AT&T with emergency after-hours or weekend contact numbers wherein support can be obtained in the event of unavailability of the Software due to a FATAL or SEVERE IMPACT Error. If a FATAL Error is reported after hours, or during the
weekend, Supplier shall begin workaround/temporary fix activities as soon as possible 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 99 









 Software and Professional Services Agreement 

 


	15.	Special Terms and Conditions: 

  

	 	a.	Invoice/Billing 

 Invoices and billing information are to be sent electronically to:

 <Enter applicable AT&T Business Unit/Finance Name>: <email@att.com> 

Copies of all invoices are to be sent to: 

<AT&T Contact Name> 

<Title> 
 <Street and
Room> 
 <City, State Zip> 

<email@att.com> 

AT&T will notify Amdocs of any changes regarding invoices and billing information at <Enter Phone Number
(xxx)xxx-xxxx> or email: <NAME@amdocs.com>. 
  

	16.	Payment Terms: 

 Payment terms for invoices issued under this Order shall be in
accordance with Section 3.19, “Invoicing and Payment” of the Master Services Agreement, which is, as of the Effective Date of this Order, net [***] days from the date of receipt of the invoice. 

 

	17.	Ownership of Paid-For Development: 

 For the
avoidance of doubt, and for purposes of interpreting AT&T’s right to Program Material and Documentation created hereunder, title to all Work output hereunder shall be determined in accordance with the Master Services Agreement,
Section 3.27, “Ownership of Paid-For Development, Use and Reservation of Rights”. 
  

	18.	Information: 

 In addition to all other rights provided by Section 3.16,
“Information”, pursuant to the Master Services Agreement, any Information received by Amdocs from AT&T or other parties engaged in this Work shall be considered and treated as confidential Information under the Order, regardless of any
requirement to put it in writing under the Master Services Agreement or separate Non-Disclosure Agreement (NDA). 
  

	19.	Termination: 

 The Termination and Partial Termination provisions applicable to this
Order are contained in Section 3.36, “Termination”, of the Master Services Agreement. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 100 









 Software and Professional Services Agreement 

 

 IN WITNESS WHEREOF, the Parties have caused this Order to be
executed as of the Effective Date. 
  

									
	Amdocs, Inc.	 		 	AT&T Services, Inc.
					
	By:	 	  
	 		 	By:	  	  

	Name:	 	 <Supplier Signatory Name>
	 		 	Name:	  	 <AT&T Signatory Name>

	Title:	 	 <Supplier Signatory Title>
	 		 	Title:	  	 <AT&T Signatory Title>

	Date:	 	  
	 		 	Date:	  	  



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 101 









 Software and Professional Services Agreement 

 

 Appendix B, Exhibit 2 – For use when issuing a Purchase Order 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 102 









 Software and Professional Services Agreement 

 

 Statement of Work 

No. 53258.<X>.<XXX> 

Between 
 Amdocs, Inc. 

And 
 AT&T Services, Inc. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 103 









 Software and Professional Services Agreement 

 

 Statement of Work 

This Statement of Work (“SOW”) is by and between Amdocs, Inc., a Delaware corporation (“Supplier” or “Amdocs”), and AT&T
Services, Inc., a Delaware corporation (“AT&T”), and shall become a part of a Purchase Order which is governed pursuant to the terms and conditions of Master Services Agreement Number 53258.C (the “Master Services
Agreement”), which by this reference are incorporated as if fully set forth herein. Any terms and conditions in this SOW that vary from or are inconsistent with the terms and conditions of the Software Master Agreement Number 24340.C, formerly
03032360 (the “Software Master Agreement”) or the Master Services Agreement shall apply to this SOW only, and shall survive the Termination or expiration of the Master Services Agreement or the Software Master Agreement. 

For the avoidance of doubt, terms and conditions preprinted on any Purchase Order, Purchase Order acceptance or acknowledgement (if any) shall not be given
any effect as they are superseded by the terms and conditions herein. 
  

	1.	AT&T Agreement Number: 53258.<X>.<XXX> must appear on all invoices  


Amdocs Order Number: <Enter No.> 
  

	2.	Term of Services: Effective dates are <Month, DD, YYYY>, through <Month, DD, YYYY>. 

  

	3.	Project Name and Description: <Enter Details> 

  

	4.	The Custom Software and Program Material and/or Scope of Other Services Ordered: 

 This
SOW is to <Enter specific details> 
  

	5.	Third Party Software: <Enter here if any; “None” is acceptable> 

  

	6.	Additional Items Ordered: <Enter here if any; “None” is acceptable> 

  

	7.	Milestones/Resources: 

  

	 	a.	Milestones: 

 Planned milestones as of the Effective Date of this SOW are as follows:

 <Table below is an example and may be modified as required> 

 

									
	 Milestone No.
	  	Description	 	  	Date	 
	 1
	  				  			


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 104 









 Software and Professional Services Agreement 

 


	 	b.	Offshore Resources: 

 Amdocs Offshore resources working on this SOW may be located at AT&T-approved locations found in the Master Services Agreement, and at the following address(es): 

<Address Number Street and Room> 

<City, State/Province Zip> 

<Country> 
 Amdocs
Offshore resources can only access AT&T Systems/data in accordance with the Master Services Agreement, Appendix D, “Security and Offshore Requirements”. 
  

	 	c.	USA-Based Resources: 

 Amdocs USA-based resources shall work pursuant to the general directions provided by AT&T to Amdocs towards the assigned milestones but shall not in any way be deemed to be employees of AT&T. 

 

	 	d.	Staffing Details: 

 Planned roles and full time equivalent (“FTE”) resources
needed: 
 <Table below is an example and may be modified as required> 

 

							
	 Role
	  	USA-Based FTEs	  	Offshore FTEs	  	Total
	 	  	 	  	 	  	 
	 	  	 	  	 	  	 

  

	8.	Deliverables/Release Items: 

 Amdocs will provide the deliverables and/or release items
for the Project as defined in this Section and the table below. 
 <Table below is an example and may be modified as required> 

 

							
	 Milestone No.
	  	Deliverable	  	Description	  	Estimated Delivery
Date
		  		  		  	
		  		  		  	

  

	9.	Application Components: <Enter details below, “None” is acceptable and delete table> 


The following applications are included in the scope of this SOW. 
  

							
	 MOTS ID
	  	Application Name	  	% of time spent on Application	 
	 Total
	  	 	100	% 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 105 









 Software and Professional Services Agreement 

 


	10.	Amdocs Responsibilities: <Enter details below, “None” is acceptable> 

 In
addition to providing the deliverables herein, Amdocs will be responsible for the following: 
  

	 	•	 	<List additional Amdocs Responsibilities> 

  

	11.	AT&T Responsibilities: <Enter details below, “None” is acceptable> 


In addition to AT&T Responsibilities defined in Section 3.43f of the Master Services Agreement, AT&T will be responsible for the
following: 
  

	 	•	 	<List additional AT&T Responsibilities> 

  

	12.	Compensation: 

 This is a <fixed price or Time and Materials (“T&M”)>
SOW for the total amount of <Enter amount> for the Work effort. The total price is based on <Enter basis for pricing, e.g. rate, monthly or hourly, any proration, and/or assumed hours>. 

<Enter Travel and living expenses language in accordance with the Master Services Agreement, if applicable> 

The following table represents the payment schedule for this SOW: 

Payment Schedule: 

<Table below is an example and may be modified as required> 
  

									
	 Activity During
	  	FTEs	  	Rate	  	Total Invoice	  	Invoice Date
		  		  		  		  	
		  		  		  		  	
		  		  		  		  	
	Total	  		  		  		  	

  

	13.	Project Managers: 

 AT&T: 

<AT&T Contact Name> 

<Title> 
 <Street and
Room> 
 <City, State Zip> 

<email@att.com> 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 106 









 Software and Professional Services Agreement 

 

 Amdocs: 

<Amdocs PM Contact Name> 

<Title> 
 <Street and
Room> 
 <City, State Zip> 

<email@amdocs.com> 
  

	14.	Liquidated Damages for Delay in Delivery And/Or Error Severity Level Description And Resolution Plan 


<Note: the following paragraph contains the instructions and agreed upon general use of this section between the Parties. Which
clause to use will be dependent on the Project.> 
 The Parties agree that applying Liquidated Damages for Delay in Delivery and/or the
Error Severity Level Description And Resolution Plan may be applied based on the Custom Software development Services provided in the SOW. The Parties also agree that the Error Severity Level Description And Resolution Plan may apply to OnGoing
Support SOWs following Warranty. 
  

	 	a.	Liquidated Damages for Delay in Delivery 

 Upon discovery of anything indicating a
reasonable certainty that Software and/or Services will not be delivered by the scheduled Delivery Date, Supplier shall notify AT&T and provide the estimated length of delay. The Parties shall work jointly toward resolving the delayed
delivery. If the Parties reach agreement on an extended Delivery Date and Supplier fails to meet the extended Delivery Date, then AT&T may (i) if such delay amounts to a material breach, exercise AT&T’s termination rights
under the Master Services Agreement with respect to the applicable SOW, (ii) exercise its right to recover Liquidated Damages specified hereunder, and/or (iii) further extend the Delivery Date. No payments, progress or otherwise, made
by AT&T to Supplier after any scheduled Delivery Date shall constitute a waiver of Liquidated Damages. Delivery Dates shall be extended as and to the extent Supplier is unable to meet the original Delivery Date due to causes outside of
Supplier’s control. Such extension shall be proportionate to the delay caused by factors outside Supplier’s control.

Notwithstanding anything to the contrary in the Master Services Agreement, in the event of Supplier’s failure to meet a Delivery Date as
defined in the SOW (as it may have been extended in accordance with the terms as set forth herein) AT&T shall be entitled to Liquidated Damages according to the following schedule: 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 107 









 Software and Professional Services Agreement 

 


			
	 Days Late
	  	 Liquidated Damages

	 0-14
	  	$0
	 15-44
	  	10% of fees under the SOW
	 45-74
	  	10% of fees under the SOW
	 75+
	  	10% of fees under the SOW

 The foregoing Liquidated Damages shall be calculated cumulatively and shall be capped at a total of thirty
percent (30%) of the fees under the SOW. AT&T’s taking of Liquidated Damages for failure to meet a Delivery Date shall not preclude AT&T from claiming actual damages in excess of the Liquidated Damages; provided, however, that the
amount of Liquidated Damages taken by AT&T shall be deducted from any damages awarded to AT&T. Liquidated Damages taken by AT&T for failure to meet a Delivery Date shall be excluded from the limitations of liability set forth in the
Master Services Agreement 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 108 









 Software and Professional Services Agreement 

 


	 	b.	Error Severity Level Description And Resolution Plan 

  

	 	i.	During the term of the applicable SOW and, if Software fails to operate in conformance with the Specifications, or if the following specified errors (“Error”) occur, Supplier agrees to respond and perform as
follows: 

  

							
	1	  	FATAL: Reported problems preventing all useful work from being done or potential data loss or corruption, or Software functionality is inoperative; inability to use has a critical impact to AT&T’s operations.	  	 •  Acknowledgment

•  Work Around, temporary fix

•  Final fix, update, or new release

•  Communications
	  	 •  [***]

•  [***]

•  [***]

•  [***]

				
	2	  	SEVERE IMPACT: Problems disable major functions required to do productive work or Software is partially inoperative and is considered as severely restrictive by AT&T.	  	 •  Acknowledgment

•  Work around, temporary fix

•  Final fix, update, or new release

•  Communications
	  	 •  [***]

•  [***]

•  [***]

•  [***]

				
	3	  	DEGRADED OPERATIONS: Reported problems disabling specific non-essential functions; Error condition is not critical to continuing operation and/or AT&T has determined a work-around
for the Error condition.	  	 •  Acknowledgment

•  Work around, temporary fix

•  Final fix, update, or new release

•  Communications
	  	 •  [***]

•  [***]

•  [***]

•  [***]

				
	4	  	MINIMAL IMPACT: Any deviation from Specifications not otherwise included in a Severity 1, 2, or 3 category.	  	 •  Acknowledgment

•  Work around, temporary fix

•  Final Fix, update, or new release

•  Communications
	  	 •  [***]

•  [***]

•  [***]

•  [***]


  

	 	ii.	In the case of a FATAL or SEVERE IMPACT Error condition, Supplier shall use its best efforts to acknowledge notification of such Error condition within the time frames indicated. 


 

	 	iii.	Supplier shall correct any and all Errors in the Software in accordance with Error Severity Levels specified above. In addition, at any time during the Error correction or technical support process, AT&T may invoke
the below listed escalation procedure: 

  

	 	A.	Supplier’s escalation process is to ensure that when a problem is not being resolved in a satisfactory manner, (i) both AT&T and Supplier have a common perception of the nature and criticality of the
problem, (ii) the visibility of the problem is raised within Supplier’s organization, and (iii) appropriate Supplier resources are allocated toward solving the problem. 


 

	 	B.	The following escalation process may be invoked by AT&T when an Error, defect, non-conformity or technical support issue has been reported to Supplier, the Error substantially
affects AT&T’s use of the Software, and Supplier has not yet provided a patch or bypass around the Error. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 109 









 Software and Professional Services Agreement 

 


	 	C.	The escalation processes can be initiated by contacting the next higher management level within Supplier’s organization. Such Supplier designate will work with AT&T’s designated contact and management to
bring a satisfactory solution to the situation. The effort will be focused on developing an action plan and coordinating whatever Supplier resources are required to meet AT&T’s needs as rapidly as possible, within the policy stated above.


  

	 	D.	During the period of the action plan, regular status update communications will be established between AT&T’s designate and Supplier’s designate. 


 

	 	E.	If an action plan cannot be agreed to, or if the action plan fails to provide a satisfactory solution within the time frame defined in the action plan, the problem will be escalated to Supplier’s highest management
level. 

  

	 	iv.	If any FATAL or SEVERE IMPACT Software Error cannot be corrected by Supplier within the indicated timeframes, Supplier shall provide [***], that the FATAL or SEVERE IMPACT Error remains unresolved after the work
around/temporary fix resolution period specified above. [***]. 

  

	 	v.	In addition, if a FATAL Error remains unresolved [***] hours after reporting thereof by AT&T, or, if a SEVERE IMPACT Error remains unresolved [***]hours after reporting by AT&T, upon AT&T’s request,
Supplier shall provide a Software engineer at AT&T’s site(s), at no additional charge, to resolve the Software Error. 

  

	 	vi.	The Parties acknowledge that DEGRADED OPERATIONS and/or MINIMAL IMPACT Errors are generally less serious than FATAL or SEVERE IMPACT Errors. The Parties further acknowledge and agree that elongated resolution of such
Errors can be detrimental to AT&T’s use of the Software. Therefore, in the event that DEGRADED OPERATIONS Errors remain unresolved [***]days after AT&T’s initial report of the Error and AT&T’s notice of required resolution
to Supplier, or MINIMAL IMPACT Errors remain unresolved [***] days after AT&T’s report of the Error and AT&T’s notice of required resolution to Supplier, Supplier shall [***], for each day beyond[***] days for DEGRADED OPERATIONS
Errors and/or [***] days for MINIMAL IMPACT Errors that the Error remains unresolved. [***]. 

  

	 	vii.	Supplier shall provide AT&T with toll-free telephone hotline assistance related to operation of the Software, including questions about individual features or suspected malfunctions. In addition, Supplier shall
provide AT&T with emergency after-hours or weekend contact numbers wherein support can be obtained in the event of unavailability of the Software due to a FATAL or SEVERE IMPACT Error. If a FATAL Error is reported after hours, or during the
weekend, Supplier shall begin workaround/temporary fix activities as soon as possible 

  

	15.	Special Terms and Conditions: 

  

	 	a.	Invoice/Billing 

 Invoices and billing information are to be sent electronically to:

 <Enter applicable AT&T Business Unit/Finance Name>: <email@att.com> 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 110 









 Software and Professional Services Agreement 

 

 Copies of all invoices are to be sent to: 

<AT&T Contact Name> 

<Title> 
 <Street and
Room> 
 <City, State Zip> 

<email@att.com> 

AT&T will notify Amdocs of any changes regarding invoices and billing information at <Enter Phone Number
(xxx)xxx-xxxx> or email: <NAME@amdocs.com>. 
  

	16.	Payment Terms: 

 Payment terms for invoices issued under this SOW shall be in accordance
with Section 3.19, “Invoicing and Payment” of the Master Services Agreement, which is, as of the Effective Date of this SOW, net [***] days from the date of receipt of the invoice. 

 

	17.	Ownership of Paid-For Development: 

 For the
avoidance of doubt, and for purposes of interpreting AT&T’s right to Program Material and Documentation created hereunder, title to all Work output hereunder shall be determined in accordance with the Master Services Agreement,
Section 3.27, “Ownership of Paid-For Development, Use and Reservation of Rights”. 
  

	18.	Information: 

 In addition to all other rights provided by Section 3.16,
“Information”, pursuant to the Master Services Agreement, any Information received by Amdocs from AT&T or other parties engaged in this Work shall be considered and treated as confidential Information under the SOW, regardless of any
requirement to put it in writing under the Master Services Agreement or separate Non-Disclosure Agreement (NDA). 
  

	19.	Termination: 

 The Termination and Partial Termination provisions applicable to this SOW
are contained in Section 3.36, “Termination”, of the Master Services Agreement. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 111 









 Software and Professional Services Agreement 

 

 Appendix C – Offshore Locations 

The Parties agree that the following are AT&T-approved locations as of the Effective Date of this Agreement and
any modifications to this list shall be managed in accordance with Section 3.24. 
  

									
	 	  	 Country(ies) where services are
authorized by AT&T to be performed
(physical
location address is also
required if the Services involve
Information Technology-related work or
if a “virtual” or “work-from-home”
address is authorized)
	  	 City(ies) where services will be
performed for
AT&T
	  	 Services to be performed
at
approved Physical Location
	  	
Name of Supplier /
Supplier Affiliate, and/or

Subcontractor
performing the
services

					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 112 









 Software and Professional Services Agreement 

 


									
	 	  	 Country(ies) where services are
authorized by AT&T to be performed
(physical
location address is also
required if the Services involve
Information Technology-related work
or if a “virtual” or “work-from-home”
address is authorized)
	  	 City(ies) where services will be
performed for
AT&T
	  	 Services to be performed
at
approved Physical Location
	  	
Name of Supplier /
Supplier Affiliate, and/or

Subcontractor
performing the
services

					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Brazil
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Canada
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 Cyprus
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 113 









 Software and Professional Services Agreement 

 


									
	 	  	 Country(ies) where services are
authorized by AT&T to be performed
(physical
location address is also
required if the Services involve
Information Technology-related work or
if a “virtual” or “work-from-home”
address is authorized)
	  	 City(ies) where services will be
performed for
AT&T
	  	 Services to be performed
at
approved Physical Location
	  	
Name of Supplier /
Supplier Affiliate, and/or

Subcontractor
performing the
services

					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 India
	  	[***]	  	[***]	  	[***]	  	[***]


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 114 









 Software and Professional Services Agreement 

 


									
	 	  	 Country(ies) where services are
authorized by AT&T to be performed
(physical
location address is also
required if the Services involve
Information Technology-related work
or if a “virtual” or “work-from-home”
address is authorized)
	  	 City(ies) where services will be
performed for
AT&T
	  	 Services to be performed
at
approved Physical Location
	  	
Name of Supplier /
Supplier Affiliate, and/or

Subcontractor
performing the
services

					
	 India
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 India
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 India
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 India
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Israel
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Mexico
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Mexico
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Mexico
	  	 [***]
	  	 [***]
	  	 [***]
	  	 [***]

					
	 Mexico
	  	 [***]
	  	 [***]
	  	 [***]
	  	
[***]



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 115 









 Software and Professional Services Agreement 

 


									
	 	  	 Country(ies) where services are
authorized by AT&T to be performed
(physical
location address is also
required if the Services involve
Information Technology-related work
or if a “virtual” or “work-from-home”
address is authorized)
	  	 City(ies) where services will be
performed for
AT&T
	  	 Services to be performed
at
approved Physical Location
	  	
Name of Supplier /
Supplier Affiliate, and/or

Subcontractor
performing the
services

					
	 Mexico
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 UK
	  	[***]	  	[***]	  	[***]	  	[***]
					
	 UK
	  	[***]	  	[***]	  	[***]	  	[***]


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 116 









 Software and Professional Services Agreement 

 

 Appendix D – Security and Offshore Requirements: 

Supplier Information Security Requirements (“SISR”); Offshore Information Technology Services Requirements; Requirements for Offshore
Information Technology Services Requiring Elevated Rights; and Limited Offshore Remote Access (“LORA”) 
  

	1.0	AT&T Supplier Information Security Requirements (SISR) – v6.1, December 2015 


The following AT&T Supplier Information Security Requirements (“Security Requirements”) apply to Supplier (as previously defined)
when performing any action, activity or work under the agreement where any of the following occur (hereinafter referred to as “In-Scope Work”): 

 

	 	1.	The collection, storage, handling, backup, disposal, and/or access to confidential, proprietary and/or trade secret data of AT&T, including data of others that AT&T is obligated to protect, if any
(hereinafter collectively referred to as “In-Scope Information”); 

  

	 	2.	Providing or supporting AT&T branded applications and/or services using non-AT&T Information Resources (as defined below); 


 

	 	3.	Connectivity to AT&T’s Nonpublic Information Resources (as defined below); 

  

	 	4.	The development of any software to AT&T’s custom specifications for which AT&T has been charged monies; or 

  

	 	5.	Website hosting and development for AT&T and/or AT&T’s customers. 

 These Security
Requirements are not intended to apply to products or applications acquired from the Supplier by AT&T for use in AT&T-controlled space by AT&T. 

With respect to personnel under Supplier’s direct control, Supplier shall ensure that its affiliates, employees and temporary workers
performing In-Scope Work are aware of these Security Requirements and are in compliance with the Security Requirements when performing In-Scope Work. 

With respect to personnel not under Supplier’s direct control, Supplier shall: 

 

	 	1.	Include these Security Requirements into its agreements with its subcontractors performing In-Scope Work and shall perform due diligence adequate to ensure compliance by such
subcontractors with these Security Requirements when performing In-Scope Work, or 

  

	 	2.	Perform due diligence adequate to ensure that each such subcontractor when performing In-Scope Work implements and complies with information security controls, policies, processes
and procedures substantially equivalent or similar to these Security Requirements. 

 Definitions: 

Unless otherwise set forth or expanded herein, defined terms shall have the same meaning as set forth in the main body of the Agreement. 

“Demilitarized Zone” or “DMZ” is a network or sub-network that sits between a
trusted internal network, such as a corporate private Local Area Network (LAN), and an untrusted external network, such as the Internet. A DMZ helps prevent outside users from gaining direct access to internal Information Resources. Inbound packets
from the untrusted external network terminate within the DMZ and are not allowed to flow directly through to the trusted internal network. All inbound packets which flow to the trusted internal network originate within the DMZ. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 117 









 Software and Professional Services Agreement 

 

 “Information Resource(s)” means systems, applications, websites, networks, network
elements, and other computing and information storage devices, including Mobile and Portable Devices (as defined below), used in conjunction with supporting AT&T and/or used by Supplier in fulfillment of its obligations under the Agreement. 

“Mobile and Portable Devices” means mobile and/or portable computers, devices, media and systems capable of being easily carried,
moved, transported or conveyed that are used in connection with the Agreement. Examples of such devices include laptop computers, tablets, USB hard drives, USB memory sticks, Personal Digital Assistants (PDAs), and wireless phones, such as
smartphones. 
 “Nonpublic Information Resources” means those Information Resources used under the Agreement to which access is
restricted and requires proper authorization and authentication. 
 “Sensitive Personal Information” or “SPI” means the
data elements listed in the “Table of AT&T SPI Data Elements” located at the end of this appendix. 
 “Security
Gateway” means a set of control mechanisms between two or more networks having different trust levels which filter and log traffic passing, or attempting to pass, between networks, and the associated administrative and management servers.
Examples of Security Gateways include firewalls, firewall management servers, hop boxes, session border controllers, proxy servers, and intrusion prevention devices. 

“Strong Authentication” means the use of authentication mechanisms and authentication methodologies stronger than the passwords
required by the applicable requirements herein. Examples of Strong Authentication mechanisms and methodologies include digital certificates, two-factor authentication, and
one-time passwords. 
 “Strong Encryption” means the use of encryption technologies with
minimum key lengths of 128-bits for symmetric encryption and 1024-bits for asymmetric encryption whose strength provides reasonable assurance that it will protect the encrypted information from unauthorized
access and is adequate to protect the confidentiality and privacy of the encrypted information, and which incorporates a documented policy for the management of the encryption keys and associated processes adequate to protect the confidentiality and
privacy of the keys and passwords used as inputs to the encryption algorithm. 
 “Supplier Entity” or “Supplier Entities”
means Supplier, its affiliates and subcontractors. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 118 









 Software and Professional Services Agreement 

 

 In accordance with the foregoing, Supplier shall: 

System Security 
  

	 	1.	Actively monitor industry resources (e.g., www.cert.org, pertinent software vendor mailing lists and websites, and information from subscriptions to automated notifications) for timely notification of all applicable
security alerts that pertain to Supplier’s Information Resources and promptly take action to address them. (Security Alerts) 

  

	 	2.	[***] scan Supplier’s Information Resources with industry-standard security vulnerability scanning software to detect security vulnerabilities. 


 

	 	3.	Deploy Intrusion Detection Systems (IDS), Intrusion Prevention Systems (IPS), or Intrusion Detection and Prevention Systems (IDP) in an active mode of operation that monitors all traffic entering and leaving Information
Resources in conjunction with the Agreement. 

  

	 	4.	Have and use a documented process to remediate security vulnerabilities in the Information Resources and apply appropriate security patches promptly based on potential risk that a given vulnerability is or can be
exploited. 

  

	 	5.	Assign security administration responsibilities for configuring host operating systems to specific individuals. 

  

	 	6.	Ensure that all of Supplier’s Information Resources are and remain ‘hardened’ including, but not limited to, removing or disabling unused networking and other computing services (e.g., finger, rlogin,
ftp, simple Transmission Control Protocol/Internet Protocol (TCP/IP) services, etc.) and installing a system firewall, Transmission Control Protocol (TCP) wrappers or similar technology. 


 

	 	7.	Change all default account names and/or default passwords. 

  

	 	8.	Limit system administrator (also known as root, privileged, or super user) access to operating systems intended for use by multiple users only to individuals requiring such high-level access in the performance of their
jobs. 

  

	 	9.	Enforce the rule of least privilege by requiring application, database, network and system administrators to restrict access by users to only the commands, data and Information Resources necessary for them to perform
authorized functions. Supplier shall ensure that the use of AT&T’s Information Resources by Supplier Entities shall only be for the performance of those Services or functions explicitly authorized in the Agreement. 


Physical Security 
  

	 	10.	Ensure that all of Supplier’s Information Resources intended for use by multiple users are located in secure physical facilities with access limited and restricted to authorized individuals only. 


 

	 	11.	Monitor and record, for audit purposes, access to the physical facilities containing Information Resources intended for use by multiple users used in connection with Supplier’s performance of its obligations under
the Agreement. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 119 









 Software and Professional Services Agreement 

 

 Network Security 

 

	 	12.	When providing Internet accessible services to AT&T, have Denial of Service (DoS/DDoS) protections in place. In addition, protect In-Scope Information by the implementation of
a network DMZ. Web servers providing service to AT&T shall reside in the DMZ. Information Resources storing In-Scope Information (such as application and database servers) shall reside in a trusted
internal network. 

  

	 	13.	If requested by AT&T, provide AT&T with a high-level copy of their logical network diagram. The network diagram needs to provide details about placement of information resources and security devices such as
(Security Gateways, servers, DMZs, IDS/IPS, DoS/DDoS protections, etc.) within the Supplier’s network that are and/or will be used to support AT&T. 

  

	 	14.	Use Strong Encryption for the transfer of In-Scope Information outside of AT&T-controlled or Supplier-controlled networks or when
transmitting In-Scope Information over any untrusted network. This also applies to In-Scope Information contained in emails or attachments to emails. 


 

	 	15.	Require Strong Authentication for any remote access use of Nonpublic Information Resources. 


Information Security 
  

	 	16.	Isolate AT&T’s applications and In-Scope Information from any other customer’s or Supplier’s own applications and information either by (i) using
physically separate servers or (ii) alternatively by using logical access controls where physical separation of servers is not implemented. 

  

	 	17.	Have procedures for the backup, recovery and eventual destruction of In-Scope Information. Such procedures shall be documented and secure, and further, be available to AT&T
upon request. 

  

	 	18.	Limit access to In-Scope Information only to authorized persons or systems. Supplier shall ensure that the use of AT&T’s In-Scope
Information by Supplier Entities shall only be for the performance of those Services or functions explicitly authorized in the Agreement. 

  

	 	19.	Have documented processes and controls in place to detect and terminate unauthorized attempts to access, collect, store, handle and/or dispose of In-Scope Information.


 Identification and Authentication 
  

	 	20.	Assign unique UserIDs to individual users. 

  

	 	21.	Have and use a documented UserID lifecycle management process that includes manual and/or automated processes for approved account creation, timely account removal, and account modification for all Information Resources
and across all environments. Such process shall include review of access privileges and account validity to be performed [***]. 

  

	 	22.	Limit failed login attempts to no more than [***] successive attempts and lock the user account upon reaching that limit. Access to the user account can be reactivated subsequently through a manual process requiring
verification of the user’s identity or, where such capability exists, can be automatically reactivated after at least [***] from the last failed login attempt. 


 

	 	23.	Terminate interactive sessions, or activate a secure, locking screensaver requiring authentication, after a period of inactivity not to exceed [***]. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 120 









 Software and Professional Services Agreement 

 


	 	24.	Use an authentication method based on the sensitivity of In-Scope Information. 

  

	 	a.	Whenever authentication credentials are stored, Supplier shall protect them using Strong Encryption. 

  

	 	b.	When passwords are used, they shall be complex and shall at least meet the following password construction requirements: 

  

	 	•	 	Be a minimum of eight (8) characters in length. 

  

	 	•	 	Include 3 of the 4 following types of characters: upper-case alphabetic, lower-case alphabetic, numeric, and special. 

  

	 	•	 	Not be the same as the UserID with which they are associated. 

  

	 	•	 	Not contain repeating or sequential characters or numbers. 

  

	 	c.	Require password expiration at regular intervals not to exceed [***] calendar days. 

  

	 	25.	When providing users with a new or reset UserID, password or other authentication credentials, use a secure method to provide this information. 


Warning Notice 
  

	 	26.	For Nonpublic Information Resource(s) that are AT&T-branded display a warning notice, or alternatively provide a link to such warning notice, on login screens/pages that
covers the following: 

  

	 	•	 	The service is restricted to authorized users; 

  

	 	•	 	Unauthorized access is a violation of the law; 

  

	 	•	 	This service may be monitored for administrative and security reasons; and 

  

	 	•	 	By proceeding the user consents to this monitoring. 

 AT&T may specify in writing
alternative warning notice content that Supplier shall use in place of the information listed above. 
 Software and Data Integrity

  

	 	27.	In environments where antivirus software is commercially available and to the extent practicable, have current antivirus software installed and running to scan for and promptly remove or quarantine viruses and other
malware. 

  

	 	28.	Separate non-production Information Resources and In-Scope Information from production Information Resources and In-Scope Information. 

  

	 	29.	Have a documented change control process including back-out procedures for all production environments. 


 

	 	30.	For applications which utilize a database that allows modifications to In-Scope Information: (a) for applications that support transaction logging have database transaction
logging features enabled, (b) for applications that do not support transaction logging have some other mechanism that logs all modifications to In-Scope Information stored within the database including
timestamp, UserId and information modified. Such logs shall be retained and available to AT&T for a [***] months either on-line or on backup media. 


 

	 	31.	 (a)For all software developed under the Agreement that has been customized for AT&T, review such software to
find and remediate security vulnerabilities prior to initial deployment and upon any modifications and updates. This review and remediation process must include source code vulnerability scanning where such tools are commercially available, but can
otherwise include any combination of automated and/or manual processes and procedures. 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 121 









 Software and Professional Services Agreement 

 


	 	
Scan results and remediation plans must be made available to AT&T upon request. (b)Where technically feasible, for all software used, furnished and/or supported under the Agreement, review
such software to find and remediate security vulnerabilities prior to initial deployment and upon any modifications and updates based on potential risk that a given vulnerability is or can be exploited. 


 

	 	32.	Perform quality assurance testing for the security components (e.g., testing of identification, authentication and authorization functions), as well as any other activity designed to validate the security architecture,
during initial implementation and upon any modifications and updates. 

 Monitoring and Auditing Controls 

 

	 	33.	Restrict access to security logs to authorized individuals, and protect security logs from unauthorized modification. 

  

	 	34.	Review, on [***], all anomalies from security and security-related audit logs and document and resolve logged security problems in a timely manner. 


 

	 	a.	Such reviews may initially be performed by automated processes that promptly issue alarms and/or alerts when such processes detect significant anomalies so that the issuance of such alarms and/or alerts causes prompt
investigation and review by responsible individuals; and 

  

	 	b.	If automated processes successfully resolve a logged security problem, no further action by responsible individuals is required. 


Reporting Violations 
  

	 	35.	Have and use a documented procedure to be followed in the event of a suspected attack upon, intrusion upon, unauthorized access to, loss of, or other security breach involving
In-Scope Information in which Supplier shall: 

  

	 	a.	Promptly investigate and make a determination if such an attack has occurred; and 

  

	 	b.	In the event that a successful attack has occurred involving In-Scope Information or it is impossible to determine whether the attack was successful then Supplier shall promptly
notify AT&T by contacting: 

  

	 	1.	Asset Protection by telephone at 800-807-4205 from within the US and at 1-908-658-0380 from elsewhere, and 

  

	 	2.	Supplier’s contact within AT&T for Service-related issues. 

  

	 	36.	After notifying AT&T whenever there is a successful attack upon, intrusion upon, unauthorized access to, loss of, or other breach of In-Scope Information, provide AT&T
with regular status updates, including, but not limited to, actions taken to resolve such incident, at mutually agreed intervals or times for the duration of the incident and, within [***] days of the closure of the incident, provide AT&T with a
written report describing the incident, actions taken by the Supplier during its response and Supplier’s plans for future actions to prevent a similar incident from occurring. 


Mobile and Portable Devices 
  

	 	37.	Use Strong Encryption to protect all of In-Scope Information stored on Mobile and Portable Devices. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 122 









 Software and Professional Services Agreement 

 


	 	38.	Use Strong Encryption to protect all of In-Scope Information transmitted using or remotely accessed by network-aware Mobile and Portable Devices. 


 

	 	39.	Have documented policies, procedures and standards in place which ensure that any Mobile and Portable Devices used to access and/or store In-Scope Information: 


 

	 	a.	Are in the physical possession of authorized individuals; 

  

	 	b.	Are physically secured when not in the physical possession of authorized individuals; or 

  

	 	c.	Have any In-Scope Information stored on such devices promptly and securely deleted when such devices are not in the physical possession of authorized individuals nor otherwise
physically secured. 

  

	 	40.	Prior to allowing access to In-Scope Information stored on or through the use of Mobile and Portable Devices, Supplier shall have and use a documented process to ensure that:


  

	 	a.	The user is authorized for such access; and 

  

	 	b.	The identity of the user has been authenticated. 

  

	 	41.	Implement a documented policy that prohibits: 

  

	 	a.	The use of any Supplier-issued Mobile and Portable Devices to access and/or store In-Scope Information unless the device is administered and/or managed by Supplier, and


  

	 	b.	The use of any non-Supplier issued Mobile and Portable Devices to access and/or store In-Scope Information, as in cases where Supplier has
a “Bring Your Own Devices” (BYOD) program, unless adequately segregated and protected such as by a Supplier administered and/or managed secure container-based solution. 


Security Gateways 
  

	 	42.	Require Strong Authentication for administrative and/or management access to Security Gateways, including, but not limited to, any access for the purpose of reviewing log files. 


 

	 	43.	Have and use documented controls, policies, processes and procedures to ensure that unauthorized users do not have administrative and/or management access to Security Gateways, and that user authorization levels to
administer and manage Security Gateways are appropriate. 

  

	 	44.	[***], ensure that each rule was properly authorized and is traceable to a specific business request, that all rule sets end with a “DENY ALL” statement. 


 

	 	45.	Use monitoring tools to ensure that all aspects of Security Gateways (e.g., hardware, firmware, and software) are operational at all times. Ensure that all non-operational
Security Gateways are configured to deny all access. 

 Wireless Networking 

 

	 	46.	When using radio frequency (RF) based wireless networking technologies to perform or support Services for AT&T, ensure that all of In-Scope Information transmitted is
protected by the use of appropriate encryption technologies sufficient to protect the confidentiality of In-Scope Information; provided, however, that in any event such encryption shall use no less than key
lengths of 256-bits for symmetric encryption and 256-bits for asymmetric encryption. The use of RF-based wireless headsets,
keyboards, microphones, and pointing devices, such as mice, touch pads, and digital drawing tablets, is excluded from this requirement. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 123 









 Software and Professional Services Agreement 

 


	 	47.	Regardless of whether radio frequency (RF) based wireless networking technologies are in use by the Supplier, where technically feasible, perform scans [***] to detect unauthorized wireless networks and promptly take
appropriate action to eliminate them. 

 Connectivity Requirements 

 

	 	48.	In the event that Supplier has, or will be provided, connectivity to AT&T’s or AT&T’s customers’ Nonpublic Information Resources in conjunction with this Agreement, then Supplier shall not
establish interconnection to AT&T’s and AT&T’s customers’ Nonpublic Information Resources without the prior consent of AT&T and: 

  

	 	a.	Use only the mutually agreed upon facilities and connection methodologies to interconnect AT&T’s and AT&T’s customers’ Nonpublic Information Resources with Supplier’s Information Resources.


  

	 	b.	If the agreed upon connectivity methodology requires that Supplier implement a Security Gateway, maintain logs of all sessions using such Security Gateway. Such session logs must include sufficiently detailed
information to assist with a security incident or a forensic investigation (e.g. identification of the end user or application accessing AT&T). Such session logs must include origination IP address, destination IP address, ports/service
protocols used and duration of access. Such session logs must be retained for a minimum of [***]. 

  

	 	c.	When presented with evidence by AT&T of a threat to AT&T or AT&T’s customers’ Nonpublic Information Resources originating from the Supplier’s network (e.g. worm, virus or other malware, bot
infection, Advanced Persistent Threat (APT), DoS/DDoS attack, etc.), promptly cooperate with AT&T to isolate and terminate the threat. In addition, Supplier shall provide AT&T with a written plan to prevent any such future threats within
[***] after mitigation of the threat. In the event Supplier fails to cooperate with AT&T in resolving the threat AT&T reserves the right to terminate the appropriate Order and/or Agreement. 


Protection of AT&T’s SPI 
  

	 	49.	Use Strong Encryption to protect AT&T’s SPI when transmitted over any network. 

  

	 	50.	Use Strong Encryption to protect AT&T’s SPI when stored. 

 Table of AT&T SPI
Data Elements 
 Data elements in the following table are classified as AT&T Sensitive Personal Information (SPI) when they
apply to an employee, contractor, customer or supplier, except where explicitly stated otherwise and must be treated as such when used in their entirety, unless explicitly stated in the following table. This is true for all data formats including
scanned images, PDFs, JPGs, etc. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 124 









 Software and Professional Services Agreement 

 


			
	 Data Element
	  	 Description

	Driver’s License Number	  	
		
	Nationally-Issued Identification Number	  	 Includes visa and/or passport values and non-U.S. identification numbers.
Excludes U.S. SSN which is a separate data element.

		
	State or Province-Issued Identification Number	  	 Other than Driver’s License Number which is a separate data element.

		
	 Social Security Number (SSN)
  

Applies to U.S.1 only.
	  	 Includes U.S. Social Security Number, and U.S. Taxpayer ID when it is the U.S. Social Security Number of an
individual.

		
	Credit Card Number	  	 Primary Account Number (PAN) for all types of credit or debit cards - corporate, personal, etc.

		
	Bank Account Number	  	 Includes all types of bank accounts (savings, checking, etc.), both personal and business in an individual’s name.
Excludes bank routing number.

		
	 Customer Authentication Credentials
 Applies to
Customers only.
	  	 Values used by customers to authenticate and permit access to:

 
 •   the customers’ non-public personal information, including Customer Proprietary Network Information (CPNI) and AT&T Sensitive Personal Information (SPI), or

 
 •   an application enabling
the customer to subscribe to, or unsubscribe from, AT&T services, or
  

•   an AT&T service the customer is subscribed to For example: PINs, Passwords or Passcodes.
Excludes Card Security Codes.

		
	 Customer Authentication Credential Hints
  

Applies to Customers only.
	  	 Answers to questions used to retrieve customer authentication credentials, for example mother’s maiden
name.

		
	Location-Based Information (LBI)	  	 Information that identifies the current or past location of a specific individuals’ mobile device. This element
contains two factors both of which must be present and able to be associated with each other:



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 125 









 Software and Professional Services Agreement 

 


			
	 Data Element
	  	 Description

		  	 (1) a mobile device’s location (a map address, or latitude and longitude together with altitude where known) derived
from the device’s network connectivity and/or positioning system (e.g., GPS), rather than as a result of user action (e.g., email, SMS), and
  

(2) an individual’s identity derived from a unique identifier assigned to that mobile device such as customer name, MSISDN, IMSI, IMEI
or ICCID.

		
	Date of Birth (DOB)	  	 Full and complete DOB, i.e., including Month, Day and Year. Excludes partial DOB where only Month and Day are used
without Year.

		
	Biometric Data	  	 Measures of human physical and behavioral characteristics used for authentication purposes, for example fingerprint,
voiceprint, retina or iris image. Excludes templates that contain discrete data points derived from Biometric Data that do not hold the complete biometric image, where the template cannot be reverse engineered back to the original biometric
image.

		
	 Criminal History
  

Applies to non-U.S.2 only.
	  	 Information about an individual’s criminal history, e.g., criminal check portion of a background
check.

		
	 Racial or Ethnic Origin
  

Applies to non-U.S.2 only.
	  	 Data specifying and/or confirming an individual’s racial or ethnic origin.

		
	 Trade Union Membership
  

Applies to non-U.S.2 only
	  	 Data specifying and/or confirming an individual is a member of a trade union outside of the U.S.

		
	 Information Related to an Individual’s Political Affiliation, Religious Belief, or Sexual Orientation

 
 Applies to non-U.S.2 only.
	  	 Data specifying and/or confirming an individual’s political affiliation, religious or similar beliefs, or sexual
life or orientation.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 126 









 Software and Professional Services Agreement 

 


			
	 Data Element
	  	 Description

		
	 Protected Health Information (PHI)
  

Applies to U.S.1 only.
	  	 Includes any health information used in AT&T’s Group Health Care plans or belonging to AT&T’s customers
that identifies the individual or for which there is a reasonable basis to believe it can be used to identify the individuals that includes information about:
  

•   the individual’s past, present or future physical or mental health or condition,

 
 •   the provision of health
care to the individual, or
  

•   the past, present, or future payment for the provision of health care to the individual Health
information of retirees, employees, or employee beneficiaries used by AT&T for purposes other than a group health plan is not PHI.

		
	 Medical and Health Information
  

Applies to non-U.S.2 only.
	  	 Information concerning physical or mental health or condition. Includes disability information.


 Footnotes to Table of SPI Data Elements: 
  

	1.	Where SPI data elements have the term “Applies to U.S. only.” associated with them, that data element is to be classified as AT&T Proprietary (Sensitive Personal Information) when applied to data belonging
to US citizens, irrespective of whether their data is handled inside or outside the US. 


	2.	Where SPI data elements have the term “Applies to non-U.S. only.” associated with them, that data element is to be classified as AT&T Proprietary (Sensitive Personal
Information) when applied to data belonging to citizens of countries other than the US, irrespective of whether their data is handled inside or outside the US. 

  

	2.0	Offshore Information Technology Services Requirements 

 In the event Supplier currently
provides or will be providing Offshore Information Technology Services in conjunction with this Agreement, then, in addition to the foregoing, the following requirements shall apply to Supplier: 

 

	 	1	Strong authentication controls must be established for firewalls, firewall management servers, and firewall hop boxes. Options for strong authentication may include two-factor
authentication methods such as tokens, smart-cards and/or one-time passwords. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 127 









 Software and Professional Services Agreement 

 


	 	2	Supplier must ensure that firewall configurations are hardened by selecting a sample of firewalls and verifying that the default rule set ensures the following: 


 

	 	a.	IP source routing is disabled. 

  

	 	b.	Loopback address is prohibited from entering the internal network, 

  

	 	c.	Anti-spoofing filters are implemented. 

  

	 	d.	Broadcast packets are disallowed from entering the network, 

  

	 	e.	ICMP redirects are disabled. 

  

	 	f.	Fragmented packets are dropped. 

  

	 	g.	Ruleset ends with a DENY ALL statement 

  

	 	3	Screen savers or connection timeouts are required to prevent unauthorized access to unattended workstations. 

  

	 	4	Perform [***] revalidations on the user account list on firewalls, firewall management servers, and firewall hop boxes to ensure that only those users authorized for access to manage these devices have an account. This
includes the need to revalidate the authorization level of each user account to ensure appropriate permission levels are maintained. 

  

	 	5	Production support personnel and development personnel must have enough separation and auditable controls to ensure that standard change management procedures are always consistently followed. 


 

	 	6	Developers cannot access production platforms “at will”. For some trouble-shooting situations, developers may be provided access to production platforms but only on an “as needed basis” and for a
limited duration. All temporary access should be documented (who, what, when, where and why). 

  

	 	7	Track and approve changes to firewall rules is required and must be validated annually. Inappropriate firewall rules must be removed immediately. 


 

	 	8	Require a clean desk policy at the end of the day. 

  

	 	9A	Supplier resources shall be notified of the restriction that AT&T Data may not be downloaded and taken offsite. 

  

	 	9B	Wireless networking technologies must not be used for communicating unless the following steps are taken by Amdocs to maintain the confidentiality and integrity of the communication and to prevent unauthorized access to
the transmitting device and/or receiving device. When wireless networking technologies are used: 

  

	 	(i)	All communications over wireless networks must be transmitted via Virtual Private Network (VPN) session(s) using Strong Encryption. 

  


	 	(ii)	Strong authentication (e.g., two factor token or digital certificates) must be used for authenticating VPN access. 

  

	 	(iii)	Wireless hardware (with the exception of wireless network cards and access points) must be located in a physically secure area (e.g., in a locked wiring closet or locked machine room). 


 

	 	(iv)	All services not being used on the access point, router, and VPN concentrator must be disabled. 

  

	 	(v)	Enable Media Access Control (MAC)-based filtering so that only specified wireless cards can communicate to the access point. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 128 









 Software and Professional Services Agreement 

 


	 	10	Supplier must implement procedures to ensure that AT&T Data is not downloaded and removed by Supplier. To the extent Supplier suspects that AT&T Data may have been removed, Supplier agrees to conduct searches of
suspected persons and their belongings when exiting AT&T restricted areas and Supplier’s premises to the extent such searches are permissible by local law. 


 

	 	11	Notify individuals that removal of AT&T Data from the work area or Supplier’s premises is not allowed, to include signage that communicates this policy and that people and personal property including, without
limitation, packages, briefcases, and purses are subject to inspection prior to exiting AT&T restricted areas and Supplier’s premises. 

  

	 	12	Verify that all printed media containing AT&T Data (any information obtained from or provided by AT&T, including information about AT&T Systems, its employees and its customers) is securely stored, and that
a mechanism is in place to protect the security and privacy of AT&T Data. Procedures are required to restrict access to AT&T Data to authorized Supplier personnel only, and to ensure that all media containing AT&T Data is accounted for
and reconciled on [***] to ensure that the information is not removed from Supplier’s premises. 

  

	 	13	All access to electronic documentation of AT&T Data retained locally must be password protected and restricted to the very minimum number of Supplier personnel. Supplier must implement procedures to ensure that
AT&T Data is not downloaded and removed by Supplier personnel, including, at a minimum, searches. To the extent Supplier suspects that AT&T Data may have been removed, Supplier agrees to conduct searches of persons and their belongings when
exiting AT&T restricted areas and Supplier’s premises to the extent searches are permissible under local law. 

  

	 	14	All electronically stored or printed AT&T Data no longer needed must be shredded onsite or destroyed onsite by authorized Supplier personnel assigned to AT&T projects. Shred bins must be located in AT&T
restricted areas and locked until the shredding takes place. 

  

	 	15	A [***] Metric Report of Perimeter Security on the Supplier’s system should be reported to AT&T that consists of: 

  

	 	•	 	Location 

  

	 	•	 	Date 

  

	 	•	 	# of Intrusions 

  

	 	•	 	Type of Intrusions 

  

	 	•	 	Source 

  

	 	•	 	Destination 

  

	 	•	 	Detail 

  

	 	•	 	Actions 

 Security IDS audit logs must be retained [***] and offline for a period of at
least[***]. 
  

	 	16	Remote access to AT&T Networks or AT&T Data is prohibited. All work on AT&T projects must be performed within the AT&T restricted area on Supplier’s premises and any exceptions must be in accordance
with the Limited Offshore Remote Access in this Appendix D. Prior written exception to this prohibition must be obtained from the [***]. Supplier’s use of laptops offsite must have written approval from the [***]. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 129 









 Software and Professional Services Agreement 

 


	 	17	Randomly check Supplier-based email and internet-based email so that AT&T Data is not sent to an unauthorized recipient. Effective January 1, 2011, Amdocs must check for the AT&T Proprietary –
Restricted and AT&T Proprietary – Sensitive Personal Information markings in emails and attachments sent from Amdocs to non-AT&T personnel outside. Any unauthorized transmissions must be reported
by Amdocs in an email to the [***] promptly but in any case within [***]. 

  

	 	18	B2B VPN connections to AT&T are required to be secured from other remote connections. 

  

	 	19	Device-specific monitoring tools must be used to assure that firewall hardware is operational. 

  

	 	20	To minimize the risk exposure to visiting AT&T employees in locations that are of medium-high risk of terrorist attacks, Supplier shall take necessary security measures customary for the location. 


 

	 	21	All access points into the Supplier’s building(s) where AT&T work is being performed must be locked by either physical keys or a card key system, or controlled by a guard service to restrict access only to
authorized individuals. These mechanisms must be in working order and utilized at all times. Proper identification must be worn by all persons inside the Supplier’s building and a procedure in place to challenge those not wearing appropriate
identification in the Supplier’s building. The cable vault, electrical and telephone areas should be secured to give access only to those authorized. 

  

	 	22	Card key access lists and event logs must be reviewed by Supplier at a minimum of weekly to validate that building card key access is limited to only those individuals with a need to be in the Supplier’s building
and restricted area where AT&T work is being performed. Ensure that all keys are accounted for and limited to those individuals with a need to be in the Supplier’s building and restricted areas and all locks are changed on a regular
interval (at a minimum annually). Ensure that Supplier personnel surrender company identification, keys and access cards before leaving the premises when access to an area is no longer required or upon voluntarily or involuntarily ceasing to work
for Supplier and that the access cards are deactivated. Weekly reviews should include employee, contractor and supplier termination records and any associated unauthorized access attempts in the event logs. 


 

	 	23	Alarmed doors and monitored electronic systems are required to detect unauthorized access or access attempts with a plan to respond to and document incidents. 24/7 recorded video surveillance is required of the area
where work on AT&T projects is performed, including entry and exit points. 

  

	 	24	Prior to permitting any person access to an AT&T project source or origin code (for example, software development), and at annual intervals thereafter, Supplier must ensure that such person (employee, contractor,
subcontractor) is not on the Denied Persons List or the Specially Designated Nationals List of the US Department of Commerce – Bureau of Industry and Security. – Those lists are located at
http://www.bis.doc.gov/ComplianceAndEnforcement/ListsToCheck.htm. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 130 









 Software and Professional Services Agreement 

 

 Prior to permitting any person direct or indirect access, whether physical, virtual, or
otherwise, to any of AT&T’s company, employee, or customer information, or any of AT&T’s or AT&T’s customers’ premises, systems, software, or networks, Supplier must have a reputable security company perform a
criminal background check and verification of the identity of such person (employee, contractor, or subcontractor including onsite security guards responsible for physical security of Supplier’s premises and AT&T restricted areas, and
unescorted cleaning/maintenance personnel). 
  

	 	25	A security plan must be in place to include training of Supplier personnel to report suspicious activity/security incidents and complaints that did or could affect AT&T, to include documentation, follow-up and reporting to the AT&T IT:OFFSHORE organization and, as necessary, law enforcement. 


Information to be reported to the Executive Director of the IT:OFFSHORE organization would consist of at least: 

 

	 	•	 	Date of Incident 

  

	 	•	 	Who - Identify those involved and be descriptive (suspects, vehicles, property, license plate numbers, ) 

  

	 	•	 	What - What happened and how? 

  

	 	•	 	When - When did the incident occur? 

  

	 	•	 	Where - Where did the incident take place? 

  

	 	•	 	Action Taken – What action was taken? Was law enforcement notified? 

  

	 	26	An exercise of Supplier’s recovery strategy must be conducted annually. Within [***] days from the completion of a disaster recovery exercise by Amdocs, Amdocs will produce a documented conclusion with a corrective
action plan and proposed committed timeframes for corrective action upon which the Parties will agree within [***] days from receipt of the action plan. 

  

	 	27	Failover processes and procedures are required to support AT&T applications and these failover processes and procedures are exercised annually (at a minimum). 


 

	 	28	Business continuity communication documents, processes, and procedures must be readily available and current. 

  

	 	29	As soon as reasonably possible after the execution of this Agreement and on an annual basis thereafter, Supplier will, at no charge to AT&T, perform a security audit utilizing a reputable independent auditor, as
agreed by the Parties. Such security audit shall ensure that Supplier will strictly follow these AT&T Supplier Information Security Requirements. 

  

	3.0	Requirements for Offshore Information Technology Services Requiring Elevated Rights 

 In
the event Supplier currently provides or will be providing system, database, and or network administrator/root (or privileged, super user, or the like) access to host operating systems located on AT&T
non-public networks in conjunction with this Agreement from an Offshore Location, then, in addition to the foregoing, the following requirements shall apply to Supplier: 

 

	 	1	Access for privileged offshore users will be via a front-end Citrix farm that requires SecurID authentication, with front end Citrix servers located in a DMZ segment. An
alternative to this is an AT&T-provided Client VPN with a SecurID token used over a secure connection (NOT the public Internet) as reviewed and approved by AT&T’s Chief Security Office
(CSO). 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 131 









 Software and Professional Services Agreement 

 


	 	2	Auditing options must be enabled on any Supplier perimeter equipment which controls access to the Supplier equipment used to do AT&T work. To ensure integrity of audit log entries, all Supplier system clocks must be
synchronized to the same time source. Synchronization to AT&T clocks is not required. At a minimum, security audit log(s) must be automatically updated for the following system events: 


 

	 	a.	Successful and unsuccessful login attempts. 

  

	 	b.	Successful and unsuccessful attempts to switch to another user’s account (where applicable). 

  

	 	c.	Logoffs. 

  

	 	d.	User attempts to access files or resources outside their privilege level. 

  

	 	e.	User access to all privileged files and/or processes. 

  

	 	f.	Operating system configuration changes. 

  

	 	g.	Operating system program changes. 

  

	 	h.	All changes that can feasibly be captured, to system hardware and software. 

  

	 	i.	All security-related changes, including adding users. 

  

	 	j.	Failures for computer, program, communications, and operations. 

  

	 	k.	Starting and stopping of audit logging. 

 Security audit logs must be maintained [***] and
offline for [***]. 
  

	 	3	AT&T reserves the right to perform vulnerability scans and review the scanning results of Supplier systems in a pre-announced, scheduled manner on Supplier’s equipment on
an AT&T isolated LAN segment and Supplier Network equipment used to access AT&T Networks, systems, and data or Supplier agrees to reveal to the [***] the detailed scanning findings and closure activities related to
vulnerabilities found [***]. 

 Information to be reported to the AT&T-IT OCE
would consist of at least: 
  

	 	•	 	Date of discovery of vulnerability 

  

	 	•	 	How it was remediated 

  

	 	•	 	What was remediated 

  

	 	•	 	What are the plans to remediate 

  

	 	•	 	Estimated Date of closure 

  

	 	4	An Intrusion Prevention System (IPS) is required on Supplier’s data network to prevent unauthorized access. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 132 









 Software and Professional Services Agreement 

 


	4.0	Limited Offshore Remote Access (“LORA”) to AT&T Systems 

 The following
outlines the AT&T requirements and procedures to which the Supplier must adhere for allowance of select pre-authorized offshore Supplier personnel to have remote access to AT&T systems, for which the
Supplier is already under contract with AT&T to perform IT support services. 
 This remote access program (the “Limited Offshore
Remote Access”) set forth herein defines the program requirements and how the Supplier shall work with the AT&T Offshore Compliance and Enablement organization to determine if Supplier can utilize the LORA for an existing or new information
technology Services engagement. Examples of engagements where AT&T will consider Supplier’s request for LORA would be a Work Order where offshore Supplier personnel are required to perform after-hours work monitoring support services and
access AT&T data. 
 I. Definitions

AT&T IT Offshore Compliance & Enablement (IT OCE) – AT&T Information Technology organization that
manages oversight of the Limited Offshore Remote Access program. The IT OCE will serve as the front door and provide authorization to Supplier. IT OCE point of contact is identified below. 

“AT&T Proprietary – Restricted Information” or “Restricted Information” means: any Information that
has a higher level of sensitivity and therefore must be shared only among persons with a clear business need to know; or any Information that requires a high degree of protection by law and loss or unauthorized disclosure could require notification
by AT&T to government agencies, individuals or law enforcement; or any Information that if revealed widely could present an increased risk of compromising computer systems, fraud, or increased likelihood of disrupting business operations.
Examples of Restricted Information include, but are not limited to, unpublished financial information, designs and development plans for new or improved products, services, or processes, Customer Proprietary Network Information (CPNI), marketing
information including customer contact lists, software source code for business critical applications, other companies’ confidential information that is shared with AT&T under contract or an NDA, internal AT&T authentication credentials
(e.g., passwords, PINs and password hint answers), and security and/or network information including: logs, engineering or architecture diagrams, configuration files, firewall rules, security incident reports, and vulnerability information. 

Limited Offshore Remote Access (“LORA”)—the ability, with prior AT&T IT OCE approval, for an Offshore Supplier
resource to connect to AT&T systems via AT&T client VPN from their Resource Home Location for the purposes of completing contracted work for AT&T. 

“Remote Access Laptop”- limited in use by Amdocs Offshore resources that require a laptop to perform their day-to-day duties, who support the AT&T account, from the Amdocs facility, Resource Home Location or travel. There will be no transfer of or storage of SPI and AT&T
Proprietary – Restricted Information or Restricted Information on this device. For clarity the only access to SPI and AT&T Proprietary – Restricted Information or Restricted 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 133 









 Software and Professional Services Agreement 

 

 
Information will be as defined in Article II #3 below, “Remote Access Laptop with AT&T Data other than SPI”. 

Resource Home Location – The home residence of a Supplier resource. Each approved Supplier resource can have LORA from only one
Resource Home Location. 
 Controlled and Audited Supplier Facility – The designated offshore Supplier work location, which is
governed by controls specified by AT&T. This is the Supplier resource’s primary work location. 
 Remote Access Solution
– From the Resource Home Location, an approved Supplier resource will use a Remote Access Laptop/Desktop to connect to the AT&T Secure VPN Gateway. 

Permanent Workstation/Virtual Workstation A laptop or desktop located in a controlled and audited Supplier facility that is used to
access the AT&T network for contracted services. 
 II. LORA requirements: 

 

	 	1.	General requirements: Supplier shall adhere to the following: 

  

	 	a.	Each individual LORA user shall be reviewed and either approved or denied [***] from receipt of written request to the AT&T IT Offshore Compliance & Enablement (IT OCE). 


 

	 	b.	Each individual LORA request must be linked with a specific statement of work covered under an existing or pending Work Order issued under a current Master Agreement between AT&T and the Supplier. 


 

	 	c.	Supplier is to maintain a history log of all requests for LORA. 

  

	 	d.	Supplier is to submit all new LORA requests to IT OCE, in a format specified by AT&T. 

  

	 	e.	The IT OCE Sr. Technical Director or equivalent will approve or deny each request. 

  

	 	f.	[***] is the AT&T IT OCE interface at the time of this document being implemented. This is subject to change by AT&T. 

  

	 	g.	Supplier may also request AT&T IT OCE approval for temporary remote access from a location other than the Resource Home Location. 


 

	 	h.	Resource Home Location shall be subject to voluntary inspection /verification, as agreed upon by the Parties, by Supplier or AT&T representative if AT&T information/resource is present. The Supplier resource
must notify AT&T/Supplier of any changes in Resource Home Location. 

  

	 	i.	Amdocs will notify AT&T immediately upon an Amdocs resource’s change in status that would no longer require them to have LORA. 


 

	 	2.	[***] and immediately upon approval, all offshore Supplier personnel approved for LORA must complete Supplier-provided compliance training, which shall include but not be limited to: 


 

	 	a.	A review of all of the requirements outlined in this Agreement that pertain to the end-users of the Remote Access Solution. The review shall include but not be limited to: the use
of the Remote Access Solution from only a single Resource Home Location; the Remote Access Laptop theft/loss reporting requirements; and the prohibition of the use of the Remote Access Solution for anything other than responding to on-call situations. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 134 









 Software and Professional Services Agreement 

 


	 	b.	Review of the following guidelines: https://spsf05.web.att.com/sites/AssetProtection/APO/Investigations/LaptopThefts.aspx. 

  

	 	c.	Upon AT&T request, Supplier shall provide to the AT&T IT Offshore Compliance & Enablement (IT OCE) team confirmation that the above training has been completed annually and upon LORA approvals.


  

	 	3.	Remote Access Laptop with AT&T Data other than SPI or AT&T Proprietary – Restricted Information (“APRI”) or Restricted Information (“RI”) requirements:  


 
 



 
 Supplier shall adhere to the following: 

 

	 	a.	Supplier shall designate, provide and support the Remote Access Laptop to be used from the Resource Home Location, Amdocs Facility and travel. 


 

	 	b.	Each Remote Access Laptop shall have anti-virus and firewall software installed and operating. 

  

	 	c.	The configuration file that controls these settings required for LORA shall be read only for the user and editable only by authorized domain administrators (e.g., settings that control full hard drive encryption,
antivirus and [***], for application installations) or resources approved for LORA shall not have administrator rights on the Remote Access Laptop. 

  

	 	d.	Each Remote Access Laptop shall have a full hard drive encryption solution, such as [***], installed and operating, with all data encrypted as long as the laptop is “locked” (screensaver has turned on) or the
Remote Access Laptop is shut down. The configuration file that controls the above settings shall be read only for the user and editable only by authorized domain administrators. 


 

	 	e.	Remote Access Laptops with no [***] software or equivalent product installed must require both a password and biometric (i.e., thumb print scan) authentication for both logging into the device and “unlocking”
the device (gaining control of the device after the screensaver has turned on). The configuration file that controls the above settings shall be read only for the user and editable only by authorized domain administrators. 


 

	 	f.	Password and/or biometric-protected screensavers must be set with the inactivity timeout set to [***] minutes or less. The configuration file that controls the above settings shall be read only for the user and editable
only by authorized domain administrators. 

  

	 	g.	 Each Remote Access Laptop shall have the [***] or equivalent product installed and operating, with the
configuration file that controls the above settings set to be read only for the user and editable only by authorized domain administrators. Supplier shall initiate the [***] or equivalent data wipe process for all lost or stolen laptops within [***]
of the 



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 135 









 Software and Professional Services Agreement 

 


	 	
reported theft or loss of a Remote Access Laptop. Supplier is to notify AT&T at [***] of a lost or stolen Remote Access Laptop within [***], including in such notification a description of
AT&T information that was on the Remote Access Laptop. Supplier shall provide full and proactive cooperation with any investigation related to AT&T. In addition to Amdocs’ obligation to indemnify , in the event of such a loss of
equipment, if it is determined that the lost equipment included personnel Information (personal data such as HR information, SSN, address, etc.) and the Supplier has failed to comply with the provisions of subsections b, c, d, e, and f, above the
Supplier shall provide[***]. 

  

	 	h.	Each Remote Access Laptop shall only be able to connect to [***] network at any one time. 

  

	 	i.	Remote Access Laptops shall use either (i) a VPN connection to AT&T through AT&T’s approved Client VPN or (ii) another VPN connection to connect to the Supplier’s corporate network. The
Remote Access Laptop may not use both (i) and (ii) at the same time or any other connection method(s). 

  

	 	j.	The data and voice connection in the Resource Home Location and all associated costs shall be provided by the Supplier per the Supplier’s policy and will be either a wired or wireless connection. AT&T will not
be required to cover the charges for data and voice connections in the Resource Home Locations. Wired data connections are preferred. However, if the connection is wireless (e.g., WIFI or cellular wireless connection), the connection must be
encrypted and adequately secured. 

  

	 	k.	Supplier resources shall be notified of the restriction that AT&T Data may not be downloaded and taken offsite. 

  

	 	l.	Except where expressly stated, all aforementioned software and hardware shall be provided by the Supplier. 

  

	 	m.	Security audit logs shall be maintained by the Supplier to track system events, including login attempts, user sessions, logoffs, configuration changes, and other pertinent events and data. Logs shall be retained online
for [***] and offline for [***]. 

  

	 	n.	At all times, the Remote Access Laptop shall be kept in the possession of either the AT&T-approved offshore Supplier resource to whom Supplier has assigned the device or
Supplier personnel that are responsible for administering the LORA. 

  

	 	4.	Changes in Program: 

  

	 	a.	The Limited Remote Offshore Access program is subject to change as directed by AT&T. 

  

	 	b.	AT&T reserves the right to cancel any approved Limited Remote Offshore Access requests upon written notice to the Supplier 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 136 









 Software and Professional Services Agreement 

 

 Appendix E – Prime Supplier MBE/WBE/DVBE Participation Plan and Results 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 137 









 Software and Professional Services Agreement 

 

 Appendix E, Exhibit 1 – Prime Supplier MBE/WBE/DVBE Participation Plan 

PRIME SUPPLIER MBE/WBE/DVBE PARTICIPATION PLAN 

YEAR REPORTING: 
  

					
	PRIME SUPPLIER NAME:	  	  
	  	
	ADDRESS:	  	  
	  	
	COMPANY E-MAIL:	  	  
	  	
	TELEPHONE NUMBER:	  	  
	  	

 DESCRIBE GOODS OR SERVICES BEING PROVIDED UNDER THIS AGREEMENT: 

(What product or service is the Prime Supplier providing to AT&T) 

DESCRIBE YOUR M/WBE-DVBE OR SUPPLIER DIVERSITY PROGRAM AND THE PERSONNEL DEDICATED TO THAT PROGRAM 

(Prime Supplier should note their outreach activities to diverse suppliers, membership in National Diversity Organizations, commitment from company leadership
on engaging diversity suppliers, etc.) 
 THE FOLLOWING, TOGETHER WITH ANY ATTACHMENTS IS SUBMITTED AS AN MBE/WBE/DVBE PARTICIPATION PLAN. 

 

	1.	GOALS 

 A. WHAT ARE YOUR MBE/WBE/DVBE PARTICIPATION GOALS? 

 

					
	MINORITY BUSINESS ENTERPRISES	  	(MBEs)	  	  

			
	WOMAN BUSINESS ENTERPRISES	  	(WBEs)	  	  

			
	DISABLED VETERAN BUSINESS ENTERPRISES (DVBEs)	  		  	  


 B. WHAT IS THE ESTIMATED ANNUAL VALUE OF THIS CONTRACT:
$                     
 C. WHAT
ARE THE DOLLAR AMOUNTS OF YOUR PROJECTED MBE/WBE/DVBE PURCHASES: 
 Multiply % in A. above against contract value listed in B. above

  

			
	 MINORITY BUSINESS ENTERPRISES (MBEs)
	  	$                                    



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 138 









 Software and Professional Services Agreement 

 


			
	 WOMAN BUSINESS ENTERPRISES (WBEs)
	  	$                            
	 DISABLED VETERAN BUSINESS ENTERPRISES (DVBEs)
	  	$                            

  

	2.	LIST THE PRINCIPAL GOODS AND SERVICES TO BE SUBCONTRACTED TO MBE/WBE/DVBEs OR DELIVERED THROUGH MBE/WBE/DVBE VALUE ADDED RESELLERS 


(What part of the Prime Suppliers supply chain provides opportunities for diversity subcontracting) 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 139 









 Software and Professional Services Agreement 

 

 Appendix E, Exhibit 2 – MBE/WBE/DVBE Results Report 

MBE/WBE/DVBE RESULTS REPORT 
 DETAILED
PLAN FOR USE OF MBE/WBE/DVBEs AS SUBCONTRACTORS, DISTRIBUTORS, VALUE ADDED RESELLERS 
 For every product and service you intend to use, provide the
following information. 
 (attach additional sheets if necessary) 
  

									
	 Company Name
	  	 Classification (MBE/WBE/
DVBE)
	  	 Products/Services to be
provided
	  	 $ Value
	  	 Date to Begin



SELLER AGREES THAT IT WILL MAINTAIN ALL NECESSARY DOCUMENTS AND RECORDS TO SUPPORT ITS EFFORTS TO ACHIEVE ITS MBE/WBE/DVBE PARTICIPATION GOAL(S). SELLER ALSO
ACKNOWLEDGES THE FACT THAT IT IS RESPONSIBLE FOR IDENTIFYING, SOLICITING AND QUALIFYING MBE/WBE/DVBE SUBCONTRACTORS, DISTRIBUTORS AND VALUE ADDED RESELLERS. 

THE FOLLOWING INDIVIDUAL, ACTING IN THE CAPACITY OF MBE/WBE/DVBE COORDINATOR FOR SELLER, WILL: 

Administer the MBE/WBE/DVBE Participation Plan, submit summary reports, and cooperate in any studies or surveys as may be required in order to
determine the extent of compliance by the Seller with the participation plan. 
 In accordance with Section 3.42, Supplier shall email a
copy of the annual plan to [***]. Thereafter, Supplier shall furnish its [***] results to AT&T in accordance with instructions to be provided to Supplier following AT&T’s receipt of Supplier’s initial annual plan. When reporting
results, Supplier shall count only expenditures with entities that are certified as MBE, WBE, or DVBE firms by Third Party certifying agencies recognized by AT&T, as listed on http://www.attsuppliers.com. 

 

					
	NAME:	 	  
	 	
			
	TITLE:	 	  
	 	
			
	TELEPHONE NUMBER:	 	  
	 	
			
	AUTHORIZED SIGNATURE:	 	  
	 	
			
	DATE:	 	  
	 	


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 140 









 Software and Professional Services Agreement 

 

 Appendix F – Acceptance Letter 

Acceptance Letter 

[Print on AT&T Letterhead Stationery] 

[Date] 
 [Name] 

[Supplier Name] 
 [Street Address] 

[City], [State] [Zip] 
 Attn: 

In accordance with Section 3.0, “General Terms”, of that certain Master Services Agreement 53258.C, between [Supplier Name] and
AT&T, effective [Effective Date], the undersigned accepts the Custom Software described on Order [Order No.] to the above-mentioned Agreement as of [Date of Acceptance]. 

 

					
	 AT&T Services, Inc.
	 	
			
	 By:
	 	  
	 	
			
	 Print Name:
	 	  
	 	
			
	 Title:
	 	  
	 	
			
	 Date:
	 	  
	 	


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 141 









 Software and Professional Services Agreement 

 

 Appendix G – Agreement Regarding
Non-Employment Status with AT&T 
 This Agreement (“Agreement”) dated
                             is made by the individual named below (“I” or “me”), who is
engaged to perform work at              [Insert name of AT&T company that worker will be doing work for.]
                                     (“AT&T Company”),
as a worker of Amdocs, Inc. (“Supplier”) under the terms and conditions of the agreement named below, between Supplier and AT&T Services, Inc. 
  

	a.	Status 

 I have been hired by Supplier as a full or part-time employee, a temporary worker, or as an
independent contractor and Supplier will be providing services to AT&T Company. I understand that no employment relationship between me and the AT&T Company is created by this Agreement or by my agreement with the Supplier to provide
services to Supplier or AT&T Company. 
 I acknowledge and agree that Supplier shall be solely responsible for all payments to me including payment of
compensation, premium payments for overtime, bonuses, and other incentive payments, if any, and payments for vacation, holiday, sick days or other personal days, if any. Also, I will be solely responsible for negotiating and agreeing with Supplier
for participation in any Supplier benefit plans, including any pension, savings, or health and welfare plan. Unless AT&T Company expressly provides otherwise in writing, I further understand and agree that I am not eligible to participate in or
receive any benefits under the terms of the AT&T Company’s pension plans, savings plans, health plans, vision plans, disability plans, life insurance plans, stock option plans, or any employee benefit plan sponsored by the AT&T Company
for any period of time. I understand and agree that the cash payments and benefits which I receive from Supplier shall represent the sole compensation to which I am entitled, and that Supplier will be solely responsible for all matters relating to
compliance with all employer tax obligations arising from the performance of Services in connection with this Agreement. These tax obligations include but are not limited to the obligation to withhold employee taxes under local, state and federal
income tax laws, unemployment compensation insurance tax laws, state disability insurance tax laws, social security and Medicare tax laws, and all other payroll tax laws or similar laws. 

 

	b.	Work Policies and Rules 

  

	 	i.	I understand that it is my responsibility to ensure that my personal conduct and comments in the workplace are ethical, evidence a high degree of integrity, and support a professional environment free of
(i) inappropriate behavior, language, jokes or actions; (ii) harassment or biased, demeaning, offensive, or derogatory behavior to others based upon race, color, religion, national origin, sex, age, sexual orientation, marital status,
veteran’s status or disability; or (iii) violence. I further agree to refrain from (i) words or conduct that is threatening, intimidating and/or disrespectful of others, (ii) bringing a firearm or other weapon on any AT&T
premises; and (iii) using data services on a wireless device, such as texting or accessing the mobile web or other distracting activities, while driving to or from AT&T’s premises or while operating a vehicle in the performance of any
work for AT&T. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 142 









 Software and Professional Services Agreement 

 


	 	ii.	If AT&T Company provides me access to its computer systems, I agree (a) to use such systems in a professional manner, (b) to use such systems only for business purposes and solely for the purposes of
performing under the agreement named below, (c) to use such systems in compliance with AT&T Company’s applicable standards and guidelines for computer systems use, and (d) to use password devices, if applicable and if requested by
AT&T Company. Without limiting the foregoing, AT&T Company property, including but not limited to Intranet and Internet services, shall not be used for personal purposes or for any purpose which is not directly related to the business which
is the subject of the agreement named below. I acknowledge and agree that I must have a valid AT&T Company business reason to access the Intranet and/ or the Internet from within AT&T Company’s private corporate network.


  

	c.	Administrative Terms 

  

	 	i.	This Agreement shall be effective as of the date executed below, and shall remain in effect notwithstanding my termination of employment with Supplier or termination of my work at AT&T Company.


  

	 	ii.	In the event that any provision of this Agreement is held to be invalid or unenforceable, then such invalid or enforceable provisions shall be severed, and the remaining provisions shall remain in full force and effect
to the fullest extent permitted by law. 

 I have read, understand and agree to abide by this Agreement. 

By:
                                         
                                         
                 
 Date:
                                         
                                         
              
 Print Name:
                                         
                                         
   
 AT&T User ID (if assigned)
                                         
                  
 Address:
                                         
                                         
        
 Agreement No. between Supplier and AT&T:
                               

Effective Date:
                                         
                                       

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 143 









 Software and Professional Services Agreement 

 

 Appendix H – Vendor Expense Policy 

 

	1.0	General 

 The AT&T Vendor Expense Policy (VEP) provides guidelines to be followed by
all vendors of AT&T in requesting reimbursement for business travel, meals and other business related expense. Expenses outside this policy are not reimbursable. 

The following principles apply to requests for expense reimbursement: 

When spending money that is to be reimbursed, vendors must ensure that an AT&T Company (“Company”) receives proper value in
return. 
 Personal expenditures reported for reimbursement should be billed exactly as they were incurred. The use of averages for any type
expenditure or combination of expenditures is not permitted except as specifically provided or documented in a contract. 
 Every vendor and
AT&T employee who certifies or approves the correctness of any voucher or bill should have reasonable knowledge the expense and amounts are proper and reasonable. In the absence of the adoption of such policy, or existing contractual agreements,
these guidelines are considered the minimum requirements for requesting reimbursement of Company funds. 
 Deviations from this VEP must
be approved in writing by the sponsoring Senior Manager or Officer of an AT&T Company. 
 Receipts will be requested and reviewed for
any unusual or out of the ordinary expenses or where the approver cannot make a reasonable determination of the propriety of the invoice without a receipt. 
  

	1.1	Non-Reimbursable Expenses 

 The following is a
list, although not all inclusive, of expenses considered not reimbursable: 
  

	 	•	 	Airline club membership fees, dues, or upgrade coupon 

  

	 	•	 	Baggage fees beyond the first piece of luggage 

  

	 	•	 	Barber/Hairstylist/Beautician Expenses 

  

	 	•	 	Birthday cakes, lunches, balloons, and other personal celebration/recognition costs 

  

	 	•	 	Break-room supplies for the vendor, such as coffee, creamer, paper products, soft drinks, snack food 

  

	 	•	 	Car rental additional fees as an example: Global Positioning System (GPS) devices, or fee charged for airline frequent flyer miles. 

  


	 	•	 	Car Washes 

  

	 	•	 	Clothing, personal care items, and toiletries 

  

	 	•	 	Credit card fees 

  

	 	•	 	Dependent care 

  

	 	•	 	Entertainment expenses 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 144 









 Software and Professional Services Agreement 

 


	 	•	 	Expenses associated with spouses or other travel companions 

  

	 	•	 	Expenses to cover meals or expenses for an AT&T employee, whether in a home location or on official travel 

  

	 	•	 	Flowers, cards and gifts 

  

	 	•	 	Health Club and Fitness facilities 

  

	 	•	 	Hotel pay-per-view movies, Video Games and/or mini bar items 


 

	 	•	 	Hotel no-show or cancellation charges 

  

	 	•	 	Insurance for rental car and or flight 

  

	 	•	 	Internet access in hotels (added to 3.5) 

  

	 	•	 	Laundry (except when overnight travel is required for 7 or more consecutive nights) 

  

	 	•	 	Lawn care 

  

	 	•	 	Lost: luggage, cash, personal items and valuables, and tickets 

  

	 	•	 	Magazines & newspapers 

  

	 	•	 	Meals not consistent with AT&T’s Global Employee Expense Policy and or meals not directly required for doing business on the AT&T account (e.g. vendors cannot voucher lunch with each other simply to talk
about AT&T) 

  

	 	•	 	Medical supplies 

  

	 	•	 	Membership fees to exercise facilities or social/country clubs 

  

	 	•	 	Movies purchased while on an airplane 

  

	 	•	 	Office expenses of vendors for example: a calendar 

  

	 	•	 	PC, cell phone, and other vendor support expenses (unless specifically authorized in the agreement) 

  

	 	•	 	Personal entertainment 

  

	 	•	 	Phone usage / Wi-Fi on airline unless prior written approval by AT&T 

  

	 	•	 	Safe rentals during a hotel stay 

  

	 	•	 	Souvenirs, personal gifts 

  

	 	•	 	Surcharges for providing fast service (not related to delivery charges such as FedEx, UPS, etc.). AT&T expects all vendors to complete the terms of contracts in the shortest period practicable. Charges for
shortening the timeframe in which contracts are fulfilled are not permissible. 

  

	 	•	 	Tips for housekeeping and excessive tips, i.e., in excess of 15% to 18% of cost of meal or services, excluding tax 

  

	 	•	 	Tobacco Products 

  

	 	•	 	Traffic or Parking Fines 

  

	 	•	 	Travel purchased with prepaid air passes. 

  

	 	•	 	Upgrades on airline, hotel, or car rental fees 

  

	 	•	 	Water (bottled or dispensed by a supplier), (unless authorized for specific countries where it is recommended that bottled water is used) 


 

	 	•	 	Fee charged for advanced reservation for airport parking 

  

	 	•	 	Supplier shall not bill for travel, meal, or living expenses when its employees are working from their own homes or office locations or at an AT&T location that is one hour’s driving time or less away from the
employees’ residences or office locations. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 145 









 Software and Professional Services Agreement 

 

 The failure to comply with the above mentioned restrictions will result in the Company
refusing payment of charges or pursuing restitution from the vendor. 
  

	2.0	Responsibilities 

  

	2.1	Vendor’s Responsibility 

 Vendors are responsible for ensuring clarification of any
questions from sponsoring AT&T managers relative to reimbursable business expenses. 
 It is mandatory that financial transactions are
recorded in a timely manner. 
 Out-of-pocket business
expense(s) for vendors that are not submitted for reimbursement within 90 calendar days from the date incurred are considered non-reimbursable. 

Company managers who are responsible for approving reimbursable expenses of vendors should ensure they are submitted and approved in a timely
manner. 
  

	3.0	Travel Policy 

 Vendors must first consider the feasibility of using videoconferencing or
teleconferencing as an alternative to travel. Travel that is to be reimbursed by AT&T should be incurred only as necessary and pre-approved by AT&T (unless otherwise authorized in the agreement). 

AT&T reserves the right to dispute any expense submittal and if not verifiable as valid may reject reimbursement. Reimbursements will be
made to vendor only after expenses are verified as valid. 
  

	3.1	Travel Authorization 

 Travel requiring overnight stays must be pre-approved by the sponsoring AT&T 3rd Level Manager or above and should be approved only if it is necessary for the vendor to travel to perform required work. 

 

	3.2	Travel Reservations 

 Vendors are expected to procure the most cost efficient travel
arrangements, preferably equivalent to the AT&T discount rate. AT&T does not reimburse for travel purchased with prepaid air passes. 
  

	3.3	Travel Expense Reimbursement 

 Vendor travel expenses incurred for company business are
reimbursable only as specified in these guidelines. Travel expenses may include the following: 
  

	 	•	 	Transportation (airfare or other commercial transportation, car rental, personal auto mileage, taxi and shuttle service) 

  

	 	•	 	Meals and lodging 

  

	 	•	 	Parking and tolls 

  

	 	•	 	Tips/porter service (if necessary and reasonable) 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 146 









 Software and Professional Services Agreement 

 


	 	•	 	Vendors who stay with friends or relatives or other vendor employees while on a Company business trip will NOT be reimbursed for lodging, nor will they be reimbursed for expenditures made to reciprocate their
hospitality by buying groceries, being host at a restaurant, etc. 

 The expense must be ordinary and necessary, not lavish or
extravagant, in the judgment of the AT&T sponsoring management. Any reimbursement request must be for actual expenditures only. 
  

	3.4	Air Travel Arrangements 

 Vendors must select lowest logical coach airfare (fares
available in the market at the time of booking, preferably well in advance of trip to attain lowest possible airfare). Vendors must consider non-refundable fares, routing requiring one additional interim stop
in each direction, or an alternate flight within 2 hours of the original departure and arrival time. First class bookings are not reimbursable. Vendors can request business class when a single segment of flight time (“in air time”
excluding stops, layovers and ground time) is greater than 8 continuous hours providing the relevant manager pre-approves. 
  

	3.5	Hotel Arrangements 

 AT&T has established Market-Based Room Rate Guidelines for
vendors to reference when making hotel reservations in the United States. Vendors should contact their AT&T sponsoring manager to receive guidance for hotel rates when traveling in the U.S. Sponsoring managers may access Travel Central to obtain
information on the AT&T U.S. Market Guidelines. Vendors traveling outside the U.S. should reference the GSA, Government Per Diem as a guide: https://aoprals.state.gov/web920/per_diem.asp. Non-US vendors
may use these dollar per diems as a guide, but any locally specified per diems will take precedence. Vendors are expected to abide by these guidelines when making hotel arrangements or use specified AT&T preferred hotels/maximum location rates
or reasonably priced hotels outside of the U.S. The AT&T sponsoring manager can advise which hotel/max rate to use if there is a hotel in the location concerned. AT&T will only reimburse vendors up to the established room rate
guideline/AT&T preferred hotel rate in each market, or for actual hotel lodging charges incurred, whichever is less. 
 There must be a
strong business justification for incurring any cost for internet access, and a request for reimbursement must be accompanied by a detailed explanation regarding reason for charge. 

Note: Vendors must indicate the number of room nights on the transaction line when invoicing for reimbursement of hotel expenses. Copies
of all hotel bills must be made available for any invoice containing lodging charges. 
  

	3.6	Ground Transportation 

 While away from their home location overnight, vendors are
expected to utilize rapid transit or local shuttle service. If the hotel provides a complimentary shuttle, vendors are to use this service before paying for transportation. If complimentary service is not provided a taxi or other local
transportation is reimbursable as a business expense. Tips provided to taxi drivers cannot exceed 15% of the value of the total fare. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 147 









 Software and Professional Services Agreement 

 

 A rental car is appropriate when the anticipated business cost is less than that of other
available public transportation. Except to the extent necessary to accommodate several travelers and/or luggage requirements, vendors will not be reimbursed for automobile rentals other than economy or
mid-sized/intermediate models. 
 “Loss Damage Waiver” and “Extended Liability
Coverage” are not considered reimbursable in the US. Prepaid fuel or refueling charges at the time of return are not reimbursable. Rental cars should be refueled before returning to the rental company, since gas purchased through the rental
company carries an expensive refueling service charge. 
  

	3.7	Use of Personal Vehicle 

 When use of personal vehicle is required for business travel,
AT&T will reimburse for daily mileage for amounts over 50 miles (first 50 miles not reimbursable). This includes parking and toll fees. Vendors/suppliers should provide the following information: 

 

	 	•	 	Purpose of the trip 

  

	 	•	 	Date 

  

	 	•	 	Starting Point and Destination 

  

	 	•	 	Mileage log –when combining numerous trips, a mileage log should be provided showing the total mileage of the daily trips less the 50 miles not allowed for reimbursement (See Section 3.16, “Expenses
Incurred in the vicinity of home/work location” below). 

  

	3.8	Parking 

 If airport parking is necessary, vendors must use long term parking facilities.
Additional costs for short term, valet or covered parking are not reimbursable. 
  

	3.9	Entertainment 

 Entertainment expense is not reimbursable to vendors. Entertainment
includes meal expense involving AT&T personnel, golf fees, tickets to events and related incidental expenses. Hotel charges for a pay-per-view movie, individual
sightseeing tours, or other individual activities (i.e., golf, sporting event, movie, etc.) are not reimbursable. 
  

	3.10	Laundry and Cleaning 

 Reasonable laundry charges during business trips of seven or more
consecutive nights are reimbursable based on actual expenses incurred. 
  

	3.11	Communications 

  

	 	•	 	The actual cost of landline telephone calls for AT&T business is reimbursable. The use of AT&T products is required when available. 


 

	 	•	 	AT&T will not reimburse vendors for cell phone bills unless approved under the contract. With prior consent of the sponsoring AT&T Senior Manager, only individual calls that exceed a vendor’s rate
plan that are necessary to conduct business for AT&T may be reimbursed. 

  

	 	•	 	Charges for high speed internet access are not reimbursable unless specifically approved in the contract. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 148 









 Software and Professional Services Agreement 

 


	3.12	Business Meals (Travel and Non-Travel) 

 Vendors
when dining alone on an out-of-town business trip are expected to spend $62 USD or less per day inclusive of tax and gratuity for meals within the U.S. and $153 USD
equivalent or less per day inclusive of tax and gratuity for meals outside the U.S. except where governed by law or mandatory per diem. This includes all meals purchased during the day. Vendors should take into consideration the travel destination
and exercise good judgment in incurring reasonable meal expenses. 
 AT&T managers authorizing invoices will be held accountable for
ensuring that vendors are following this policy and are spending Company funds economically. 
  

	3.13	Flowers, Greeting Cards, Gifts and Incentive Awards 

 The cost of gifts, flowers,
birthday lunches, or greeting cards is considered a personal expense and is not reimbursable. For example, vendors making a donation or providing a gift for a fund-raiser for AT&T may not submit such an expense to AT&T for reimbursement.

  

	3.14	Loss or Damage to Personal Property 

 The Company assumes no responsibility for loss or
damage to a vendor’s personal property during business functions or hours. 
  

	3.15	Publications 

 Subscriptions to or purchases of magazines, newspapers and other
publications are not reimbursable. 
  

	3.16	Expenses incurred in the vicinity of home/work location 

 Supplier shall not bill for
travel, meal or living expenses when employees are working from their own homes, office locations or an AT&T location that is within 50 miles of the employees’ residence or work location. 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 149 









 Software and Professional Services Agreement 

 

 Appendix I – Non-Disclosure Agreements


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 150 









 Software and Professional Services Agreement 

 

 Appendix I, Exhibit 1 – Non-Disclosure
Agreement between Amdocs and external auditors for AT&T 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 151 









 Software and Professional Services Agreement 

 

 NON-DISCLOSURE AND CONFIDENTIALITY AGREEMENT

 THIS NON-DISCLOSURE AND CONFIDENTIALITY AGREEMENT 

(“Agreement”) is made as of the ∎ day of ∎, ∎ 

BETWEEN: 
 AMDOCS INC., a corporation organized and
existing under the laws of the State of Delaware, having its principal offices at 1390 Timberlake Manor Parkway, Chesterfield, MO 63017 (hereinafter referred to as “AMDOCS”); 

AND 
 ∎ a ∎[corporation,
partnership, etc.] organized and existing under the laws of ∎, having its principal offices at ∎ (hereinafter referred to as the “Receiving Party”). 

WHEREAS AMDOCS (or any of its affiliated companies) is the owner and/or author of and/or has the right to license certain valuable proprietary
routines, computer programs, documentation, trade secrets, systems, methodology, know-how, marketing and other commercial knowledge, techniques, specifications, plans and other proprietary information, whether
in oral, written, graphic, electronic, or any other form or medium whatsoever, including any related ideas and look-and-feel, which are referred to in this Agreement as
“the AMDOCS Proprietary Information”; and 
 WHEREAS AT&T SERVICES, INC. (“AT&T”) would like the Receiving Party to
provide it with certain services (the “Services”); and 
 WHEREAS in order to perform the Services, the Receiving Party must have
access to the AMDOCS Proprietary Information, and AMDOCS agrees to provide the Receiving Party with such access to the AMDOCS Proprietary Information, subject to the Receiving Party first obligating itself to confidentiality by signing this
Agreement. 
 NOW THEREFORE, the parties agree as follows: 
  

	1.	In this Agreement, “AMDOCS Confidential Information” means the software and any other AMDOCS Proprietary Information received by the Receiving Party from AT&T or Amdocs where the AMDOCS Proprietary
Information is clearly so marked or where the Receiving Party has otherwise been made aware that the AMDOCS Proprietary Information is confidential. For greater certainty, if AMDOCS notifies the Receiving Party that certain AMDOCS Proprietary
Information already disclosed is confidential, that AMDOCS Proprietary Information shall become AMDOCS Confidential Information under this Agreement. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 152 









 Software and Professional Services Agreement 

 


	2.	The Receiving Party agrees to hold in confidence the AMDOCS Confidential Information, including derivatives thereof in any form (e.g., reports or analyses relating to such information, whether or not provided by
AMDOCS), and to refrain from copying, distributing, disseminating or otherwise disclosing the AMDOCS Confidential Information to anyone, other than to employees of the Receiving Party who have a need to know such information for
purposes of performing the Services. 

  

	3.	Furthermore, the Receiving Party hereby undertakes: 

  

	 	a.	not to use the AMDOCS Confidential Information for any purposes other than performance of the Services; 

  

	 	b.	not to sell, grant, make available to, or otherwise allow the use of the AMDOCS Confidential Information by any third party, directly or indirectly; and 


 

	 	c.	not to use, directly or indirectly, the AMDOCS Confidential Information in the development and/or sale of software systems, for itself or for a third party, and/or in the provision of any services to a third party,
except for the Services to be provided by the Receiving Party to AT&T. 

  

	4.	Upon the termination or expiration of this Agreement for any reason or upon the conclusion of the Services and/or at the request of AMDOCS, the Receiving Party shall: 


 

	 	a.	return to AMDOCS any document or other material in tangible form in its possession being part of the AMDOCS Confidential Information; and 


 

	 	b.	destroy any document or other material in tangible form that contains the AMDOCS Confidential Information together with confidential and/or proprietary information of a third party, and confirm such destruction in
writing to AMDOCS. 

  

	5.	Disclosure of the AMDOCS Confidential Information to the Receiving Party may be made in writing or other tangible form, electronically, or by demonstration of any product. 


 

	6.	Disclosure of the AMDOCS Confidential Information to the Receiving Party shall in no way serve to create, on the part of the Receiving Party, a license to use, or any proprietary right in, the AMDOCS Confidential
Information or in any other proprietary product, trade mark, copyright or other right of AMDOCS. 

  

	7.	Any use by the Receiving Party of the AMDOCS Confidential Information permitted under this Agreement is conditioned upon the Receiving Party first taking the safeguards and measures required to secure the
confidentiality of such Proprietary Information. Without limiting the generality of the foregoing, the Receiving Party shall draw to the attention of its employees who will have access to the AMDOCS Confidential Information, all the obligations
concerning the AMDOCS Confidential Information contained in this Agreement, and shall require each and every such employee to sign a written acknowledgment with respect to such obligations substantially in the form of the Annex attached hereto and
made a part hereof. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 153 









 Software and Professional Services Agreement 

 


	8.	The confidentiality obligations of the Receiving Party regarding the AMDOCS Confidential Information shall have not apply to such information which: 


 

	 	a.	becomes public domain without fault on the part of the Receiving Party; 

  

	 	b.	is lawfully obtained by the Receiving Party from any source other than AMDOCS, free of any obligation to keep it confidential; 

  

	 	c.	is previously known to the Receiving Party without an obligation to keep it confidential, as can be substantiated by written records; 


 

	 	d.	is expressly released in writing from such obligations by AMDOCS; or 

  

	 	e.	is required to be disclosed pursuant to law, regulation, judicial or administrative order, or request by a governmental or other entity authorized by law to make such request; provided, however, that the Receiving Party
first notifies AMDOCS to enable it to seek relief from such requirement, and renders reasonable assistance requested by AMDOCS (at AMDOCS’ expense) in connection therewith. 


 

	9.	This Agreement shall be in full force and effect for a period of seven (7) years commencing on the date first stated above. However, the provisions of Section 3.c. above shall survive the termination and/or
expiration of this Agreement for any reason. 

  

	10.	The Receiving Party acknowledges that a breach of this Agreement may cause AMDOCS extensive and irreparable harm and damage, and agrees that AMDOCS shall be entitled to injunctive relief to prevent use or disclosure of
its Proprietary Information not authorized by this Agreement, in addition to any other remedy available to AMDOCS under applicable law. 

  

	11.	This Agreement constitutes the entire agreement between the parties and supersedes any prior or contemporaneous oral or written representation with regard to the subject matter hereof. This Agreement may not be modified
except by a written instrument signed by both parties. 

  

	12.	If, however, any provision of this Agreement is determined to be invalid or unenforceable, such invalidity or unenforceability shall not invalidate or render unenforceable the entire Agreement, but rather the entire
Agreement shall be construed as if not containing the particular invalid or unenforceable provision or provisions, and the rights and obligations of the parties shall be construed and enforced accordingly. In addition, the parties hereby agree to co-operate with each other to replace the invalid or unenforceable provision(s) with a valid and enforceable provision(s) which will achieve the same result (to the maximum legal extent) as the provision(s)
determined to be invalid or unenforceable. 

  

	13.	This Agreement shall be governed and construed under the laws of the State of New York, USA without giving effect to its provisions regarding conflicts of law. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 154 









 Software and Professional Services Agreement 

 

 IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first stated above.

  

									
	AMDOCS, INC. 	 		 		 	∎
					
	By:	 	  
	 		 	By:	 	  

					
	Name:	 	  
	 		 	Name:	 	  

					
	Title:	 	  
	 		 	Title:	 	  

					
	Date:	 	  
	 		 	Date:	 	  



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 155 









 Software and Professional Services Agreement 

 

 [ANNEX TO NON-DISCLOSURE AND CONFIDENTIALITY
AGREEMENT] 
 ACKNOWLEDGMENT OF NON-DISCLOSURE OBLIGATIONS 

I have read and understand the Non-Disclosure and Confidentiality Agreement dated
                    between AMDOCS INC. and
                    , and agree to be bound by all the provisions of that Agreement as if I were a party thereto. 

 

	
	  

	Signature
	  

	Name
	  

	Employer
	  

	Title
	  

	Date



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 156 









 Software and Professional Services Agreement 

 

 Appendix I, Exhibit 2 – Non-Disclosure between
a vendor, consultant, or third party to AT&T and AT&T 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 157 









 Software and Professional Services Agreement 

 

 NON-DISCLOSURE AGREEMENT 

THIS AGREEMENT, effective on the date when signed by the last Party (“Effective Date”), is between <AT&T Company>, a <AT&T
State Inc> corporation, on behalf of itself and its Affiliates (collectively “AT&T”), and <Supplier Name>, a <Supplier State Inc> corporation, on behalf of itself and its Affiliates (collectively the “Receiving
Party”). Each Party may be referred to in the singular as “Party” or in the plural as “the Parties” to this Agreement. 
 The
Parties agree as follows: 
  

	1.	In connection with ongoing discussions or negotiations between AT&T and the Receiving Party concerning Project Name (the “Project), AT&T may find it beneficial to disclose to the Receiving Party certain
confidential or proprietary information in written, oral or other tangible or intangible forms, which may include, but is not limited to, discoveries, ideas, concepts, know-how, techniques, designs,
specifications, drawings, blueprints, tracings, diagrams, models, samples, flow charts, data, computer programs, disks, diskettes, tapes, marketing plans, customer names and other technical, financial or business information (individually and
collectively, “Information”). Information provided by AT&T or its contractors shall be deemed to be confidential and proprietary unless otherwise exempt as specified below. 


 

	2.	The Receiving Party understands that, except as otherwise agreed in writing, the Information which it may receive concerning AT&T’s future plans with respect to the Project is tentative and is not intended to
represent firm decisions concerning the implementation of such plans. Information provided by AT&T does not represent a commitment to purchase or otherwise acquire any products or services from the Receiving Party. If AT&T desires to
purchase or otherwise acquire any products or services from the Receiving Party, the Parties will execute a separate written Agreement to govern such transactions. 


 

	3.	The Receiving Party shall: 

  

	 	a.	hold such Information in confidence with the same degree of care with which the Receiving Party protects its own confidential or proprietary Information, but no less than reasonably prudent care; 


 

	 	b.	restrict disclosure of the Information solely to its employees, contractors and agents with a need to know such Information, advise those persons of their obligations hereunder with respect to such Information, and
assure that such persons are bound by obligations of confidentiality no less stringent than those imposed in this Agreement; 

  

	 	c.	use the Information only as needed for the purposes of the Project; 

  

	 	d.	except for the purposes of the Project, not copy, distribute, or otherwise use such Information or knowingly allow anyone else to copy, distribute, or otherwise use such Information, and any and all copies shall bear
the same notices or legends, if any, as the originals; and 

  

	 	e.	upon request, promptly return to the AT&T all Information that is in tangible form; as to Information that was disclosed in intangible form, including, but not limited to electronic mail, upon request by AT&T,
the Receiving Party shall certify in writing within five (5) business days to AT&T that all such Information has been destroyed or, if the Information was recorded on an erasable storage medium, that all such Information has been erased.



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 158 









 Software and Professional Services Agreement 

 


	4.	The Receiving Party possessing or receiving Information shall have no obligation to preserve the confidential or proprietary nature of any Information which: 


 

	 	a.	was already known to the Receiving Party free of any obligation to keep it confidential at the time of its disclosure by AT&T as evidenced by the Receiving Party’s written records prepared prior to such
disclosure; or 

  

	 	b.	is or becomes publicly known through no wrongful act of the Receiving Party; or 

  

	 	c.	is rightfully received from a third person having no direct or indirect secrecy or confidentiality obligation to AT&T with respect to such Information; or 


 

	 	d.	is independently developed by an employee, contractor or agent of the Receiving Party or another party not associated with the Project and who did not have any direct or indirect access to the Information; or


  

	 	e.	is approved for release by written authorization by AT&T; or 

  

	 	f.	it is required to disclose pursuant to an order of a duly empowered government agency or a court of competent jurisdiction, provided due notice and an adequate opportunity to intervene is given to AT&T, unless such
notice is prohibited by such order. 

  

	5.	This Agreement shall apply to all Information relating to the Project disclosed by AT&T and shall continue for a period of five (5) years thereafter. The term of this Agreement is three (3) years from the
above stated Effective Date. 

  

	6.	The Information shall be deemed the property of AT&T, who exclusively shall retain all rights to such Information. Nothing contained in this Agreement shall be construed as granting or conferring any rights by
license or otherwise in any such Information to the Receiving Party. 

  

	7.	This Agreement shall benefit and be binding upon the Parties hereto and their respective Affiliates, successors and assigns. For the purposes of this Agreement, the term “Affiliate” means (1) a company,
whether incorporated or not, which owns, directly or indirectly, a majority interest in either Party (a “parent company”), and (2) a company, whether incorporated or not, in which a five percent (5%) or greater interest is owned,
either directly or indirectly, by: (i) either Party or (ii) a parent company. 

  

	8.	NOTWITHSTANDING ANYTHING IN THIS AGREEMENT TO THE CONTRARY, AT&T MAKES NO REPRESENTATIONS OR WARRANTIES OF ANY NATURE WHATSOEVER WITH RESPECT TO ANY INFORMATION FURNISHED HEREUNDER, INCLUDING, WITHOUT LIMITATION,
ANY WARRANTIES OF MERCHANTABILITY OR FITNESS FOR A PARTICULAR PURPOSE OR AGAINST INFRINGEMENT. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 159 









 Software and Professional Services Agreement 

 


	9.	In the event the Receiving Party discloses, disseminates, or releases any confidential or proprietary Information received from AT&T, except as provided in Section 4, such disclosure, dissemination, or release
shall be deemed a material breach of this Agreement. AT&T may demand prompt return of all confidential and proprietary Information previously provided to the Receiving Party and terminate this Agreement. The provisions of this Section are in
addition to any other legal rights or remedies AT&T may have in law or in equity. 

  

	10.	This Agreement may only be changed or supplemented by a written amendment signed by authorized representatives of the Parties to this Agreement. 


 

	11.	This Agreement shall be governed by and construed in accordance with the laws of the State of Texas, irrespective of its choice of law principles. Both Parties agree to comply with all laws, including, but not limited
to, laws and regulations regarding the export of information outside the United States. The Receiving Party will not knowingly transmit, directly or indirectly, in whole or in part, any Information of AT&T, or export, directly or indirectly, any
product of the Information in contravention of the laws of the United States or the laws of any other country governing the aforesaid activities. The Receiving Party will not transfer any Information received hereunder or any product made using such
Information to any country prohibited from receiving such data or product by the U.S. Department of Commerce Export Administration Regulations without first obtaining a valid export license and written consent of AT&T. In the event the Receiving
Party violates the foregoing, it agrees to defend, indemnify, and hold harmless AT&T from and against any claim, loss, liability, expense or damage including fines or legal fees, incurred by AT&T with respect to the export or re-export activities contrary to the foregoing. Notwithstanding any other provision of this Agreement or any Supplement attached hereto, this Section shall survive any termination or expiration of this Agreement and
any Supplements attached hereto. 

 IN WITNESS WHEREOF, the Parties have caused this Agreement to be executed, which may be in
duplicate counterparts, each of which will be deemed to be an original instrument, as of the date the last Party signs. 
  

									
	<Supplier Name>	 		 	AT&T Services, Inc.


									
					
	By:	 	  
	 		 	By:	 	  



									
					
	Printed Name:	 	  
	 		 	Printed Name:	 	  



									
					
	Title:	 	  
	 		 	Title:	 	  

					
	Date:	 	  
	 		 	Date:	 	  



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 160 









 Software and Professional Services Agreement 

 

 Appendix I, Exhibit 3 – Non-Disclosure
Agreement between Supplier’s Subcontractors and Supplier 

  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 161 









 Software and Professional Services Agreement 

 

 NON-DISCLOSURE AND CONFIDENTIALITY AGREEMENT

 THIS NON-DISCLOSURE AND CONFIDENTIALITY AGREEMENT (“Agreement”) is made as of the
        day of    , 20     
 BY AND BETWEEN: 

[Systems Integrator], a corporation organized and existing under the laws of
                , having its principal offices at
                    (hereinafter referred to as “COMPANY”) 

AND 
 AMDOCS, INC. a corporation
organized and existing under the laws of Delaware, having its principal offices at 1390 Timberlake Manor Parkway, Chesterfield, MO 63017 (hereinafter referred to as “AMDOCS”). 

WHEREAS COMPANY is the owner and/or the author of and/or has the rights to disclose certain valuable proprietary documentation and business and
technical information relating to its current and future business plans, which are not generally available to the public and which COMPANY may desire to protect against unrestricted disclosure or competitive use, all of which are referred to in this
Agreement as the “COMPANY Proprietary Information”; and 
 WHEREAS AMDOCS (or any of its affiliated companies) is the owner and/or author
of and/or has the rights to license certain valuable proprietary routines, computer programs, documentation, trade-secrets, systems, methodology, know-how, marketing and other commercial knowledge, techniques,
specifications, plans and other proprietary information, including but not limited to material associated with, and forming part of, any proprietary software systems of AMDOCS, which are referred to in this Agreement as the “AMDOCS Proprietary
Information”; and 
 WHEREAS each party may, in connection with the Project, disclose to the other party information which is part of its
Proprietary Information and, therefore, the parties wish to set forth the manner in which the COMPANY Proprietary Information and the AMDOCS Proprietary Information will be treated during the Project; 

NOW THEREFORE, in consideration of the mutual agreements contained herein, the parties agree as follows: 

 

	1.	The term “Proprietary Information”, whenever relating to COMPANY’s information, shall mean the COMPANY Proprietary Information and whenever relating to AMDOCS’ information, shall mean the AMDOCS
Proprietary Information. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 162 









 Software and Professional Services Agreement 

 


	2.	The receiving party agrees to hold in confidence the disclosing party’s Proprietary Information, and to refrain from copying, distributing, disseminating or otherwise disclosing such Proprietary Information to
anyone, other than to those of its employees who have a need to know such Proprietary Information for purposes of the Project. AMDOCS’ employees are deemed to include employees of its affiliates who will be involved in the Project.


  

	3.	The receiving party undertakes not to use the Proprietary Information of the disclosing party for any purposes other than the Project, and not to sell, grant, make available to, or otherwise allow the use of the
disclosing party’s Proprietary Information by any third party, directly or indirectly, except as expressly permitted herein. 

  

	4.	In addition, COMPANY undertakes not to use, directly or indirectly, the AMDOCS Proprietary Information or any derivatives thereof in any form (e.g., reports and analyses) in the development support, and/or sale of
software systems having the same or similar functions as the Ensemble, for itself or for a third party. 

  

	5.	Upon the termination and/or expiration of this Agreement for any reason and/or upon the conclusion of the Project and/or at the request of the disclosing party, the receiving party shall: 


 

	 	a.	return to the disclosing party any document or other material in tangible form in its possession being part of the Proprietary Information of the disclosing party, unless otherwise agreed upon in writing between the
parties; and/or 

  

	 	b.	destroy any document or other material in tangible form that contains Proprietary Information of the disclosing party and the receiving party, and confirm such destruction in writing to the disclosing party.


  

	6.	Disclosure of the disclosing party’s Proprietary Information to the receiving party may be made in writing or any tangible form, electronically, or occur by demonstration of any product including but not limited to
the Amdocs Ensemble software. Proprietary Information disclosed in tangible or electronic form shall be marked by the disclosing party as proprietary and/or confidential information of such party. 


 

	7.	Disclosure of the disclosing party’s Proprietary Information to the receiving party shall in no way serve to create, on the part of the receiving party, a license to use, or any proprietary right in, the disclosing
party’s Proprietary Information or in any other proprietary product, trademark, copyright or other right of the disclosing party. 

  

	8.	The confidentiality obligations of the receiving party regarding the disclosing party’s Proprietary Information shall not apply to such Proprietary Information which: 


 

	 	a.	becomes public domain without fault on the part of the receiving party; 

  

	 	b.	is lawfully obtained from a source other than the disclosing party, free of any obligation to keep it confidential; 

  

	 	c.	is previously known to the receiving party without an obligation to keep it confidential, as can be substantiated by written records; 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 163 









 Software and Professional Services Agreement 

 


	 	d.	is expressly released in writing from such obligations by the party that owns or has the rights to such Proprietary Information; or 

  


	 	e.	is required to be disclosed pursuant to law, regulation, judicial or administrative order, or request by a governmental or other entity authorized by law to make such request; provided, however, that the receiving party
so required to disclose shall first notify the disclosing party to enable it to seek relief from such requirement, and render reasonable assistance requested by the disclosing party (at the disclosing party’s expense) in connection therewith.


  

	9.	Any use by the receiving party of the disclosing party’s Proprietary Information permitted under this Agreement is conditioned upon the receiving party first taking the safeguards and measures required to secure
the confidentiality of such Proprietary Information. Without limiting the generality of the foregoing, each party shall draw to the attention of its employees, including those employees of the affiliates referred to in Section 2 above, who
shall have access to the Proprietary Information of the other party, all the obligations concerning such Proprietary Information contained in this Agreement 

  

	10.	This Agreement shall be in full force and effect for a period of seven (7) years commencing on the date first stated above. However, the provisions of Section 7 above shall survive the termination and/or
expiration of this Agreement for any reason. 

  

	11.	Each party acknowledges that its breach of this Agreement may cause the other party extensive and irreparable harm and damage, and agrees that the other party shall be entitled to injunctive relief to prevent use or
disclosure of its Proprietary Information not authorized by this Agreement, in addition to any other remedy available to the other party under applicable law. 

  

	12.	This Agreement constitutes the entire agreement between the parties and supersedes any prior or contemporaneous oral or written representation with regard to the subject matter hereof. This Agreement may not be modified
except by a written instrument signed by both parties. 

  

	13.	If, however, any provision of this Agreement is determined by a court of competent jurisdiction to be invalid or unenforceable, such invalidity or unenforceability shall not invalidate or render unenforceable the entire
Agreement, but rather the entire Agreement shall be construed as if not containing the particular invalid or unenforceable provision or provisions, and the rights and obligations of the parties shall be construed and enforced accordingly. In
addition, the parties agree to cooperate to replace the invalid or unenforceable provision(s) with valid and enforceable provision(s) which will achieve the same result (to the maximum legal extent) as the provision(s) determined to be invalid or
unenforceable. 

  

	14.	This Agreement shall be governed by and construed under the laws of the State of New York, without giving effect to such laws’ provisions regarding conflicts of law. 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 164 









 Software and Professional Services Agreement 

 

 IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first stated above.

  

									
	 <System Integrator>

(“COMPANY”)
	 		 	 Amdocs, Inc.

(“AMDOCS”).

					
	By:	 	  
	 		 	By:	 	  



									
					
	Printed Name:	 	  
	 		 	Printed Name:	 	  



									
					
	Title:	 	  
	 		 	Title:	 	  

					
	Date:	 	  
	 		 	Date:	 	  



  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 165 









 Software and Professional Services Agreement 

 

 Appendix J—Disaster Recovery Plan (“DRP”) and Business Continuity Plan
(“BCP”) 
 Amdocs BCP/DRP Summary 

Amdocs is a global company with development centers located around the world. At Amdocs, we are totally committed to providing the best possible products and
services to our customers, and our commitment includes the ability to continue providing those products and services in the event of a major catastrophe at one of our development centers. 

Our global presence inherently supports the BCP concept. All BCP/DRP operations world-wide are coordinated by a dedicated corporate BCP/DRP team. Since all of
our development centers are interconnected, in the event of a major catastrophe, employees from damaged locations can relocate to alternate Amdocs facilities—in the same region or another region, depending on the situation—to continue
supporting customer operations. 
 Our DRP strategy is based on ongoing replication of data to other Amdocs facilities, allowing full recovery of data from
damaged sites and ensuring our capability to fully restore the damaged environment. Amdocs data centers are remotely monitored 24 x 7 x 365 and supported by technical professionals spread across the globe. In addition to DRP preparations, backups
are performed on a daily basis, and tapes are tested and shipped to off-site storage facilities on a regular basis. 

Our BCP/DRP plans are regularly tested and updated as needed to comply with changes in technologies and business needs. 

The size of the company and the level of expertise across sites allow Amdocs, in case of a catastrophic event, to send development, operational, and technical
reinforcement teams to customer sites to provide support and resolve issues following a disaster. In addition, other professional groups can be sent to assist and reinforce disaster recovery personnel. This allows Amdocs to provide ongoing support
to our customers in a disaster situation until normal operations can resume. 
 Below are the alternate BCP/DRP destinations for the Amdocs sites currently
supporting AT&T. 
  

					
	 Development Site
	  	Alternative BCP/DRP Site	 
	 Haifa
	  	 	[	***] 
	 Nazareth
	  	 	[	***] 
	 Raanana
	  	 	[	***] 
	 Negev
	  	 	[	***] 
	 Cyprus / Maritime
	  	 	[	***] 
	 India / Magarpatta
	  	 	[	***] 


  
 Proprietary and
Confidential 
 This Agreement and information contained therein is not for use or disclosure outside of AT&T, its Affiliates, and
third party 
 representatives, and Supplier except under written agreement by the contracting parties. 


  
 166