Contract Award



 Exhibit 10.16 

***Text Omitted and Filed Separately 

With the Securities and Exchange Commission. 

Confidential Treatment Requested 

Under 17 C.F.R. Sections 200.80(b)(4) 

And Rule 406 of the Securities 

Act of 1933, as amended. 
  

																															
	 	 	 	 	 	 	 	 	PAGE OF PAGES
	AWARD/CONTRACT	 	 1. THIS CONTRACT IS A RATED ORDER

    UNDER DP AS (15 CFR 700)
	 	 	 	RATING 	 	1	 	35
	 2.
CONTRACT (Proc. Inst. Ident.) NO.
 HDTRA1-10-C-0004
	 	 3. EFFECTIVE DATE

            21 Apr 2010
	 	 4. REQUISITION/PURCHASE
REQUEST/PROJECT NO.
 CBM090014890

	5. ISSUED BY	 	CODE  	 		 	  HDTRA1	 	6. ADMINISTERED BY                 (If other than Item 5)	 	CODE        	 	S0514A
	
DEFENSE THREAT REDUCTION AGENCY/BE-BC
 8725 JOHN
J. KINGMAN ROAD, MSC 6201
 FORT BELVOIR VA 22060-6201
	 	 DCMA SAN DIEGO

7675 DAGGET STREET, SUITE 200
 SAN DIEGO CA
92111-2241

	7. NAME AND ADDRESS OF CONTRACTOR (No. street, city, county, name and zip code)	 	8. DELIVERY
	 TRIUS THERAPEUTICS, INC.

JOHN SCHMID
	 		 	 	 	[    ] FOB ORIGIN [X] OTHER (See below)
	6310 NANCY RIDGE DR STE 101	 		 	 	 	9. DISCOUNT FOR PROMPT PAYMENT
	SAN DIEGO CA 92121-3209	 		 	 	 	 Net 30 Days

 

	 	 		 	 	 	 10. SUBMIT INVOICES

(4 copies unless otherwise specified)
 TO
THE ADDRESS
 SHOWN IN:
	 	1  	 	ITEM
	 	 		 		 		 		 		 		 		 	 	 	 	 	 	 
	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 
	CODE 47YA5	 	 	 	 	 	FACILITY CODE	 	 	 	 	 
	11. SHIP TO/MARK FOR	 	CODE  	 		 	HDTRA1	 	12. PAYMENT WILL BE MADE BY	 	CODE	 	HQ0339
	 DEFENSE THREAT REDUCTION
AGENCY/RD/CBM
 SEE SEPARATE LETTER

8725 JOHN J. KINGMAN ROAD, MAIL STOP 6201
 FORT
BELVOIR VA 22060
  
	 	 DFAS COLUMBUS CENTER

DFAS-COWEST ENTITLEMENT OPERATIONS
 P.O. BOX
182381
 COLUMBUS OH 43218-2381
  

	 13. AUTHORITY FOR USING OTHER THAN
FULL AND OPEN COMPETITION
 [    ] 10 U.S.C.
2304(c)(        )  [    ] 41 U.S.C. 253(c)(        )
  
	 	 14. ACCOUNTING AND APPROPRIATION
DATA
  
 See Schedule

 

	15A. ITEM NO.	 	15B. SUPPLIES/SERVICES	 	15C. QUANTITY	 	15D. UNIT  	 	    15E. UNIT PRICE	 	 	 	        15F. AMOUNT
	 	 		 	 	 		 		 		 		 	 	 		 		 		 	 
	 	 		 	 	 		 		 		 		 	 	 		 		 		 	 
	 	 		 	 	 	SEE SCHEDULE	 		 		 		 	 	 		 		 		 	 
	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 	 
	15G. TOTAL AMOUNT OF CONTRACT 	 	        $6,814,598,.00
EST
	16. TABLE OF
CONTENTS
	(X)  	 	SEC.	 	DESCRIPTION	 	 	 	 	 	 	 	PAGE(S)	 	(X)	 	SEC.	 	DESCRIPTION	 	 	 	PAGE(S)
	PART I – THE
SCHEDULE	 	PART II – CONTRACT CLAUSES
	X	 	A	 	 SOLICITATION/CONTRACT FORM
	 	1	 	X	 	I	 	CONTRACT CLAUSES	 	18 - 35
	X	 	B	 	 SUPPLIES OR SERVICES AND PRICES/COSTS
	 	2 - 4	 	PART III – LIST OF DOCUMENTS, EXHIBITS AND OTHER
ATTACHMENTS
	 	 	C	 	 DESCRIPTION/SPECS/WORK STATEMENT
	 	 	 	 	 	J	 	LIST OF ATTACHMENTS	 	 
	X	 	D	 	 PACKAGING AND MARKING
	 	5	 	PART IV – REPRESENTATIONS AND
INSTRUCTIONS
	X	 	E	 	 INSPECTION AND ACCEPTANCE
	 	6	 	 	 	K	 	REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENT OF OFFERORS	 	 
	X	 	F	 	 DELIVERIES OR PERFORMANCE
	 	7	 	 	 	 	 	 
	X	 	G	 	 CONTRACT ADMINISTRATION DATA
	 	8 - 14	 	 	 	L	 	INSTRS. CONDS. AND NOTICES TO OFFERORS	 	 
	X	 	H	 	 SPECIAL CONTRACT REQUIREMENTS
	 	15 -17	 	 	 	M	 	EVALUATION FACTORS FOR AWARD	 	 
	CONTRACTING
OFFICER WILL COMPLETE ITEM 17 OR 18 AS APPLICABLE
	
17. [X] CONTRACTOR’S NEGOTIATED AGREEMENT Contractor is required to sign this document and return] copies to issuing office.) Contractor
agrees to furnish and deliver all items or perform all the services set forth or otherwise indemnified above and on any continuation sheets for the consideration stated herein. The rights and obligations of the parties to this contract shall be
subject to and governed by the following documents. (a) this award contract, (b) the solicitation, if any, and (c) such provisions, representations, certifications, and specifications, as are attached or incorporated by reference
herein
 (Attachments are listed herein.)
	 	 18. [    ]
AWARD (Contractor is not required to sign this document) Your offer on Solicitation Number
                                         
   
  
 including the additions or changes made by you which
additions or changes are set forth in full above, is hereby accepted as to the items listed above and on any continuation sheets. This award consummates the contract which consists of the following documents: (a) the Government’s solicitation
and your offer, and (b) this award/contract. No further contractual document is necessary
  

	
19A. NAME AND TITLE OF SIGNER (Type of print)
  

John P. Schmid, CFO
	 	 20A. NAME OF CONTRACTING OFFICER

                 VICTOR E. CRAMER


                   Contracting
Officer
  
 TEL: (703)
767-8769                                    EMAIL:
VICTOR.CRAMER@DTRA.MIL

	 19B. NAME OF CONTRACTOR

 
 BY /s/ John P. Schmid
	 	 19C. DATE SIGNED

 
 4-16-10
	 	 	 	 20B. UNITED STATES OF AMERICA

 
 BY /s/ Victor E. Cramer

 
	 	 20V. DATE SIGNED

 
 4-19-2010










 HDTRA1-10-C-004 

 Page
 2
 of 35
  

 Section B - Supplies or Services and Prices 

 

												
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	0001	  		  		  	Lot	  		  	$	6,814,598.00
		  	Base	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	In accordance with Statement of Work entitled “Broad Spectrum Antibacterial Therapeutics from Marine Natural products” dated 11/30/2009 as attachment number
1.	  		  		
		  	FOB: Destination	  		  		  		  		
		  	PURCHASE REQUEST NUMBER: CBM090014890	  		  		
		  		  		  		  		  		
		  		  	[...***...]	  		  		  	 	[...***...] 
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  	$	6,814,598.00 (EST.)
						
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	000101	  		  		  		  		  	$	0.00
		  	Funding	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  	PURCHASE REQUEST NUMBER: CBM090014890	  		  		  		  		
		  		  	ESTIMATED COST	  		  		  	$	0.00
		  		  	FIXED FEE	  		  		  	$	0.00
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  	$	0.00
		  	ACRN AA	  		  		  		  	$	1,136,766.00
		  	CIN: CBM090014890000101	  		  		  		  		

  

 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page 
 3
 of 35
  


												
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	000102	  		  		  		  		  	$	0.00
		  	Funding	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  		  	ESTIMATED COST	  		  		  	$	0.00
		  		  	FIXED FEE	  		  		  	$	0.00
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  		  	$	0.00
		  	 ACRN AB
	  		  		  		  	$	3,028,710.00
		  	 CIN: CBM090014890000102
	  		  		  		  		
						
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	0002	  		  		  	Lot	  		  	$	9,854,156.00
	OPTION	  	Option Period 1	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  	PURCHASE REQUEST NUMBER: CBM090014890	  		  		  		  		
		  		  	[...***...] 	  		  		  	 	[...***...]
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  		  	$	9,854,156.00 (EST.)
						
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	0003	  		  		  	Lot	  		  	$	5,058,455.00
	OPTION	  	Option Period 2	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  	PURCHASE REQUEST NUMBER: CBM090014890	  		  		  		
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  		  	$	5,058,455.00 (EST.)

  

 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page
 4
 of 35
  


												
						
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	0004	  		  		  	Lot	  		  	$	6,823,982.00
	OPTION	  	Option Period 3	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  	PURCHASE REQUEST NUMBER: CBM090014890	  		  		  		  		
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  	$	6,823,982.00 (EST.)
						
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	0005	  		  		  		  		  	$	916,616.00
	OPTION	  	Option Task	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  	PURCHASE REQUEST NUMBER: CBM090014890	  		  		  		  		
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  	[...***...]	  		  		  	 	[...***...]
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  	$	916,616.00 (EST.)
						
	 ITEM NO
	  	 SUPPLIES/SERVICES
	  	QUANTITY	  	UNIT	  	UNIT PRICE	  	AMOUNT
	0006	  		  		  		  		  	 	NSP
		  	CDRLS	  		  		  		  		
		  	CPFF	  		  		  		  		
		  	FOB: Destination	  		  		  		  		
		  		  	ESTIMATED COST	  	$	0.00
		  		  	FIXED FEE	  		  	$	0.00
		  		  		  		  		  	 	 
		  		  	TOTAL EST COST + FEE	  	$	0.00

  

 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page
 5
 of 35 
  

 Section D – Packaging and Marking 

CLAUSES INCORPORATED BY FULL TEXT 
 252.247-9001
PACKAGING AND MARKING 
 (a) All data contained in Exhibit A, Contract Data Requirements List (CDRL), DD Form 1423 delivered under this contract
shall be delivered using best commercial practices to meet the packaging requirements of the carrier and to insure delivery, to the addressees specified on the Data Item Cover Sheet, at destination and in accordance with applicable security
requirements. 
 (b) All data and correspondence submitted to the Contracting Officer shall reference the Contract Number, the CDRL number, and
the date submitted. A copy of all correspondence sent to the Contracting Officer’s Representative (COR) or Project Manager shall be simultaneously provided to the Contracting Officer. 








 HDTRA1-10-C-004 

 Page
 6
 of 35 
  

 Section E - Inspection and Acceptance 

INSPECTION AND ACCEPTANCE TERMS 

Supplies/services will be inspected/accepted at: 
  

									
	 CLIN
	  	 INSPECT AT
	  	 INSPECT BY
	  	 ACCEPT AT
	  	 ACCEPT BY

	0001	  	Destination	  	Government	  	Destination	  	Government
	000101	  	Destination	  	Government	  	Destination	  	Government
	000102	  	N/A	  	N/A	  	N/A	  	Government
	0002	  	Destination	  	Government	  	Destination	  	Government
	0003	  	Destination	  	Government	  	Destination	  	Government
	0004	  	Destination	  	Government	  	Destination	  	Government
	0005	  	Destination	  	Government	  	Destination	  	Government
	0006	  	N/A	  	N/A	  	N/A	  	Government

 CLAUSES INCORPORATED BY REFERENCE 

 

							
	52.246-8	 		  	Inspection Of Research And Development Cost Reimbursement	  	 MAY 2001


 CLAUSES
INCORPORATED BY FULL TEXT 
 252.246-9000 INSPECTION AND ACCEPTANCE (JUL 2007) 

Government inspection and acceptance of data is specified on the Contract Data Requirements List, DD Form 1423. In accordance with FAR 52.246-8,
inspection and acceptance for all work performed at any and all times under this contract shall be the responsibility of the: 
 X Contracting
Officer’s Representative (COR) or Project Manager (PM). The Wide Area Work Flow (WAWF) Acceptor DoDDAC is located in DTRA 252.201-9000 Project Manager or DTRA 252.201-9002 Contracting Officer’s Representative. 

             Administrative Contracting Officer (ACO). The WAWF Acceptor DoDAAC can be
found in the “Administered By” block on page 1 of the contract. 
 (End of Clause) 








 HDTRA1-10-C-004 

 Page
 7
 of 35 
  

 Section F - Deliveries or Performance 

DELIVERY INFORMATION 
  

									
	 CLIN
	  	 DELIVERY DATE
	  	QUANTITY	  	 SHIP TO ADDRESS
	  	UIC
					
	 0001
	  	 POP 21-APR-2010 TO

20-OCT-2011
	  	N/A	  	DEFENSE THREAT REDUCTION AGENCY/RD-CBM SEE SEPARATE LETTER 8725 JOHN J KINGMAN ROAD, MAIL STOP 6201, FORT BELVOIR VA 22060 FOB: Destination	  	HDTRA1
					
	 000101
	  	N/A	  	N/A	  	N/A	  	N/A
					
	 000102
	  	N/A	  	N/A	  	N/A	  	N/A
					
	 0002
	  	 POP 21-OCT-2011 TO
 20-APR-2013

	  	N/A	  	DEFENSE THREAT REDUCTION AGENCY/RD-CBM SEE SEPARATE LETTER 8725 JOHN J KINGMAN ROAD, MAIL STOP 6201, FORT BELVOIR VA 22060 FOB: Destination	  	HDTRA1
					
	 0003
	  	 POP 21-APR-2013 TO
 20-JAN-2014

	  	N/A	  	(SAME AS PREVIOUS LOCATION) FOB: Destination	  	HDTRA1
					
	 0004
	  	 POP 21-JAN-2014 TO
 20-SEP-2014

	  	N/A	  	(SAME AS PREVIOUS LOCATION) FOB: Destination	  	HDTRA1
					
	 0005
	  	 POP 21-JUN-2010 TO
 20-JUN-2012

	  	N/A	  	(SAME AS PREVIOUS LOCATION) FOB: Destination	  	HDTRA1
					
	 0006
	  	 POP 21-APR-2010 TO
 20-SEP-2014

	  	N/A	  	(SAME AS PREVIOUS LOCATION) FOB: Destination	  	HDTRA1

 CLAUSES INCORPORATED BY REFERENCE 

 

					
	52.242-15	 	Stop-Work Order	  	AUG 1989
	52.242-15 Alt I	 	Stop-Work Order (Aug 1989) - Alternate I	  	APR 1984
	52.247-34	 	F.O.B. Destination	  	NOV 1991









 HDTRA1-10-C-004 

 Page
 8
 of 35 
  

 Section G - Contract Administration Data 

ACCOUNTING AND APPROPRIATION DATA 
 AA:
9790400.2620 1000 B62D 255999 BD30545000 S49012 
 AMOUNT: $1,136,766.00 

CIN CBM090014890000101: $1,136,766.00 
 AB:
9700400.2620 1000 B62D 255999 BD31540000 S49012 
 AMOUNT: $3,028,710.00 

CIN CBM090014890000102: $3,028,710.00 
 CLAUSES
INCORPORATED BY REFERENCE 
  

			
	252.232-7003	  	Electronic Submission of Payment Requests and Receiving Reports            MAR 2008


CLAUSES INCORPORATED BY FULL TEXT 
  

			
	252.201-9001	  	CONTRACTING OFFICE POINT OF CONTACT (POC)            (Dec 2007)


The POC in the Procuring Contracting Office for this contract action is See separate letter. 

CLAUSES INCORPORATED BY FULL TEXT 
  

			
	252.201-9002	  	CONTRACTING OFFICER’S REPRESENTATIVE (MAY 2007)

  

	 	a.	The Contracting Officer’s Representative (COR) for this contract is: 

  


	 	X	See Separate Letter 

 Defense
Threat Reduction Agency/             
 8725 John J. Kingman
Rd, MS 6201 
 Fort Belvoir VA 22060-6201 

Telephone number
(703)         -             

e-mail address
                        @dtra.mil. 

WAWF Acceptor DoDAAC: HDTRA1 








 HDTRA1-10-C-004 

 Page
 9
 of 35 
  

 Defense Threat Reduction
Agency/             
 1680 Texas St SE 

Kirtland AFB NM 87117-5669 

Telephone number
(505)         -             

e-mail address
                    @abq.dtra.mil. 

WAWF Acceptor DoDAAC: HDTRA2 

b. The COR will act as the Contracting Officer’s Representative for technical matters providing technical direction and discussion
as necessary with respect to the specification/statement of work and monitoring the progress and quality of the Contractor’s performance. The COR is NOT an Administrative Contracting Officer (ACO) and does not have the authority to take any
action, either directly or indirectly that would change the pricing, quality, quantity, place of performance, delivery schedule, or any other terms and conditions of the contract, or to direct the accomplishment of effort, which goes beyond the
scope of the specifications/statement of work in the contract. 
 c. When, in the opinion of the contractor, the COR requests
effort outside the existing scope of the contract, the contractor shall promptly notify the Contracting Officer in writing. No action shall be taken by the contractor under such direction until the Contracting Officer has issued a modification to
the contract or has otherwise resolved the issue. 
 CLAUSES INCORPORATED BY FULL TEXT 

 

			
	252.204-9002	  	PAYMENT INSTRUCTIONS FOR MULTIPLE ACCOUNTING CLASSIFICATION CITATIONS (AUG 2007)


In accordance with DFARS 204.7108 Payment Instructions, payment shall be made by the numbered payment instruction identified below: 

            (1) Line item specific: single funding. If there is only one source
of funding for the contract line item (i.e., one ACRN), the payment office will make payment using the ACRN funding of the line item being billed. 

    X     (2) Line item specific: sequential ACRN order. If there is more than one ACRN
within a contract line item, the payment office will make payment in sequential ACRN order within the line item, exhausting all funds in the previous ACRN before paying from the next ACRN using the following sequential order: Alpha/Alpha;
Alpha/Numeric; Numeric/Alpha; and Numeric/Numeric. 
             (3) Line
item specific: contracting officer specified ACRN order. If there is more than one ACRN within a contract line item, the payment office will make payment within the line item in the sequence ACRN order specified by the contracting officer,
exhausting all funds in the previous ACRN before paying from the next ACRN. 

            (4) Line item specific: by fiscal year. If there is more than one
ACRN within a contract line item, the payment office will make payment using the oldest fiscal year appropriations first, exhausting all funds in the previous fiscal year before disbursing from the next fiscal year. In the event there is more than
one ACRN associated with the same fiscal year, the payment amount shall be disbursed from each ACRN within a fiscal year in the same proportion as the amount of funding obligated for each ACRN within the fiscal year. 








 HDTRA1-10-C-004 

 Page
 10
 of 35 
  

             (5) Line item
specific: by cancellation date. If there is more than one ACRN within a contract line item, the payment office will make payment using the ACRN with the earliest cancellation date first, exhausting all funds in that ACRN before disbursing funds
from the next. In the event there is more than one ACRN associated with the same cancellation date, the payment amount shall be disbursed from each ACRN with the same cancellation date in the same proportion as the amount of funding obligated for
each ACRN with the same cancellation date. 
             (6) Line item
specific: proration. If there is more than one ACRN within a contract line item, the payment office will make payment from each ACRN in the same proportion as the amount of funding currently unliquidated for each ACRN. 

            (7) Contract-wide: sequential ACRN order. The payment office will
make payment in sequential ACRN order within the contract or order, exhausting all funds in the previous ACRN before paying from the next ACRN using the following sequential order: alpha/alpha; alpha/numeric; numeric/alpha; and numeric/numeric.

             (8) Contract-wide: contracting officer specified ACRN
order The payment office will make payment in sequential ACRN order within the contract or order, exhausting all funds in the previous ACRN before paying from the next ACRN in the sequence order specified by the contracting officer. 

            (9) Contract-wide: by fiscal year. The payment office will make
payment using the oldest fiscal year appropriations first, exhausting all funds in the previous fiscal year before disbursing from the next fiscal year. In the event there is more than one ACRN associated with the same fiscal year, the payment
amount shall be disbursed from each ACRN within a fiscal year in the same proportion as the amount of funding obligated for each ACRN within the fiscal year. 

            (10) Contract-wide: by cancellation date. The payment office will
make payment using the ACRN with the earliest cancellation date first, exhausting all funds in that ACRN before disbursing funds from the next. In the event there is more than one ACRN associated with the same cancellation date, the payment amount
shall be disbursed from each ACRN with the same cancellation date in the same proportion as the amount of funding obligated for each ACRN with the same cancellation date. 

            (11) Contract-wide: proration. The payment office will make payment
from each ACRN within the contract or order in the same proportion as the amount of funding currently unliquidated for each ACRN. 

            (12) Other. If none of the standard payment instructions identified
in paragraphs (d)(1) through (11) of this section are appropriate, the contracting officer may insert other payment instructions, provided the other payment instructions— 

(i) Provide a significantly better reflection of how funds will be expended in support of contract performance; and 

(ii) Are agreed to by the payment office and the contract administration office. 

CLAUSES INCORPORATED BY FULL TEXT 

252.216-9005 PROFIT OR FEE ON TRAVEL COSTS (JUL 2008) 

Travel shall not be a profit or fee bearing cost element. 

(End of clause) 








 HDTRA1-10-C-004 

 Page
 11
 of 35
  

 CLAUSES INCORPORATED BY FULL TEXT 

 

			
	252.232-9000	  	CONTRACT FUNDING PROFILE (OCT 1998)

 Subject to FAR
Clause 52.232-22, Limitation of Funds, the amount of $4,165,476 is obligated for work to be performed during the period beginning with contract award and continuing through March 30, 2011. Additional incremental funding planned, but not
obligated, is: 
 FY11  $2,649,122 

(End of clause) 
 CLAUSES INCORPORATED BY FULL
TEXT 
  

			
	252.232-9001	  	PRICES/COST

 a. Subject to the provisions of the Clauses of
this Contract entitled LIMITATION OF FUNDS, ALLOWABLE COST AND PAYMENT, and FIXED FEE, the total allowable cost under this Contract shall not exceed $             A
                     , which is the total estimated cost of the Contractor’s performance hereunder, exclusive of fixed fee. In
addition, the Government shall pay the Contractor a fixed fee of $            
B                 for the performance of this Contract. It is understood and agreed that the Government’s obligation is limited to INCREMENTAL FUNDING
in the amount of $             C                 . Within this amount
($             C                 ), the fixed fee shall bear the same relationship to the total
fixed fee, as the costs incurred bear to the total estimated cost. 
 b. Interim payment vouchers may be submitted for provisional payment
pursuant to the Clauses of this Contract entitled ALLOWABLE COST AND PAYMENT and FIXED FEE. 
 Fill in the dollar amounts as applicable:

 [...***...] 

[...***...] 
 C:  $4,165,476

 CLAUSES INCORPORATED BY FULL TEXT 
  

			
	252.232-9007	  	PAYMENT INFORMATION IN CENTRAL CONTRACTOR REGISTRATION (CCR) DATABASE


This contract contains FAR clause 52.204-7, Central Contractor Registration. All contractors must be registered in the CCR database prior
to award, during performance, and through final payment of any contract, except for awards to foreign vendors for work to be performed outside the United States. 

 

 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page
 12
 of 35 
  

 The Contractor is responsible for the accuracy and completeness of the data within the
CCR, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. In addition to the contractor’s requirement to confirm on an annual basis that its information in the CCR database is accurate and
complete, the contractor’s information in the CCR database must be updated whenever changes occur to the contractor’s remit-to data (e.g., account number, vendor name and address, etc.) and the paying office notified of any changes. The
contractor’s failure to maintain accurate information in the CCR database could result in payment delays for which the Government shall not be liable. 

CLAUSES INCORPORATED BY FULL TEXT 

252.232-9012 WIDE AREA WORK FLOW (WAWF) – RECEIPT AND ACCEPTANCE (RA) INSTRUCTIONS (September 2008) 

(a) As prescribed in DFARS clause 252.232-7003 Electronic Submission of Payment Requests (Jan 2004), Contractors must submit payment requests in
electronic form. Paper copies will no longer be accepted or processed for payment unless the conditions of DFARS clause 252.232-7003(c) apply. To facilitate this electronic submission, the Defense Threat Reduction Agency (DTRA) has implemented the
DoD sanctioned Wide Area Workflow-Receipt and Acceptance (WAWF-RA) for contractors to submit electronic payment requests and receiving reports. The contractor shall submit electronic payment requests and receiving reports via WAWF-RA. Vendors
shall send an email notification to the Contracting Officer Representative (COR), Program/Project Manager or other government acceptance official identified in the contract by clicking on the Send More Email Notification link upon submission of an
invoice/cost voucher in WAWF-RA. To access WAWF, go to https://wawf.eb.mil//.  
 ** For questions, contact the DTRA WAWF Team at
703-767-6840 or wawfhelp@dtra.mil ** 
 (b) Definitions: 

Acceptor: Contracting Officer’s Representative, Program/Project Manager, or other government acceptance official as identified in the
contract/order. 
 Pay Official: Defense Finance and Accounting Service (DFAS) payment office identified in the contract/order.

 SHIP To/Service Acceptor DoDAAC: Acceptor DoDAAC or DCMA DoDAAC (as specified in the contract/order). 

DCAA Auditor DoDAAC: Needed when invoicing on cost-reimbursable contracts. (Go to www.dcaa.mil and click on the appropriate link under the Audit
Office Locator to search for your DCAA DoDAAC.) 
  

					
	>>>>>	  	 For contracts that are administered by the Office of Naval Research (ONR):

Enter the ONR DoDAAC in the DCAA Auditor DoDAAC field in WAWF.
	  	<<<<<


 (c) WAWF Contractor Input
Information: 
 The contractor shall use the following information in creating electronic payment requests in WAWF: 

Invoice Type in WAWF: 
 If
billing for Cost Type/Reimbursable contracts (including T&M and LH), select “Cost Voucher” 
 If billing for
Firm-Fixed Price (FFP) Materials Only, select “Combo” 
 If billing for FFP Materials and Service, select
“Combo” 
 If billing for FFP Services Only, select “2-n-1 (Services Only)” 

** If the contract contains both FFP and Cost Type (including T&M and LH) line items, they must be invoiced separately on appropriate
types mentioned above. Upon the written approval of the Project Manager or Contracting Officer’s Representative, the contractor may invoice both line items in one type of invoice. 








 HDTRA1-10-C-004 

 Page
 13
 of 35 
  

 For WAWF Routing Information, See Table Below: 

 

									
	Description	 	SF 26	 	SF 33	 	SF 1449	 	DD 1155
	 	Located in Block/Section
	Contract Number	 	2	 	2	 	2	 	1
	Delivery Order	 	See Individual Order	 	4	 	2
	CAGE Code	 	7	 	15a	 	17a	 	9
	Pay DoDAAC	 	12	 	25	 	18a	 	15
	Inspection	 	 Section E (except SF 1449, See Entitled):

INSPECTION AND ACCEPTANCE

	Acceptance	 	 Section E (except SF 1449, See Entitled):

INSPECTION AND ACCEPTANCE

	Issue Date	 	3	 	5	 	3	 	3
	Issue By DoDAAC	 	5	 	7	 	9	 	6
	Admin DoDAAC	 	6	 	24	 	16	 	7
	Ship To / Service Acceptor DoDAAC	 	6	 	24	 	16	 	7
	Ship to Extension	 	Do Not Fill In
	Services or Supplies	 	Based on majority of requirement as determined by monetary value
	Final Invoice?	 	Do not change “N” (no) to “Y” (yes) unless this is the last invoice and the contract is ready for closeout.


(d) Final Invoices/Vouchers -Final Payment shall be made in accordance with the Federal Acquisition Regulation (FAR) 52.216-7, entitled
“Allowable Cost and Payment.” 
 Invoices - Invoice 2-n-1 (Services Only) and Invoice and Receiving Report (Combo)
Select the “Y” selection from the “Final Invoice?” drop-down box when submitting the final invoice for payment for a contract. Upon successful submission of the final invoice, click on the
Send More Email Notifications link to send an additional email notification to the Contracting Officer Representative (COR), Program/Project Manager or other government acceptance official identified in the contract. 

Cost Vouchers - Once the final DCAA audit is complete for cost reimbursable contracts and authorization is received to submit the final
cost voucher, select the “Y” selection from the “Final Voucher” drop-down box when submitting the final cost voucher. Upon successful submission of the final cost voucher, click on the
Send More Email Notifications link to send an additional email notification to the following email address: finalcostvouchers@dtra.mil 

(e) WAWF Training may be accessed online at http://www.wawftraining.com//. To practice creating documents in WAWF, visit practice site at
https://wawftraining.eb.mil//. General DFAS information may be accessed using the DFAS website at http://www.dod.mil/dfas//. Payment status information may be accessed using the myInvoice









 HDTRA1-10-C-004 

 Page
 14
 of 35 
  

 
system at https://myinvoice.csd.disa.mil// or by calling the DFAS Columbus helpdesk at 800-756-4571. (Select Option 1) Your contract number and shipment/invoice number will be required to
check status of your payment. Note: For specific invoice related inquiries email: wawfvendorpay@dtra.mil. Vendors shall forward any additional DTRA related WAWF questions to wawfhelp@dtra.mil. 

CLAUSES INCORPORATED BY FULL TEXT 

252.242-9003 - ASSIGNMENT OF CONTRACT ADMINISTRATION SERVICES (CAS) FUNCTIONS (AUG 2009) 

 

	a.	The contract administration functions stated in FAR 42.302(a) are assigned to: See Page 1, Section A, Block 6 of this contract. 


 

	b.	Notwithstanding that assignment, in accordance with FAR 42.202(b)(2), the following functions are determined to be best performed by the PCO and are retained by the
DTRA Contracting Office: 

 (1) FAR 42.302(a)(3) Conduct Postaward orientation conferences.

 (2) FAR 42.302(a)(20) Perform Postaward Security Administration. 

(3) FAR 42.302(a)(40) Perform engineering surveillance to assess compliance with contractual terms for schedule, cost, and
technical performance in the areas of design, development, and production. 
 (4) FAR 42.302(a)(51) In accordance
with FAR 52.244-2, consent to the placement of subcontracts which have experimental, developmental, or research work as one of its purposes. 

(5) Approval or disapproval of the data items listed on Exhibit A, DD Form 1423, Contract Data Requirements List.

 (END OF CLAUSE) 








 HDTRA1-10-C-004 

 Page
 15
 of 35 
  

 Section H - Special Contract Requirements 

RIGHTS IN MATERIAL 

RIGHTS IN MATERIAL - - [...***...] 
  

	(a)	Definitions. As used in this clause: 

  

	 	(1)	“Collection” means [...***...] this contract. 

  

	 	(2)	“Collected exclusively with government funds” means [...***...] expense. 


 

	 	(3)	“Material” refers to [...***...] above. 

  

	 	(4)	“[...***...] rights” means rights to [...***...] in whole or in part, in any manner, and for any purpose whatsoever, and to have or authorize
others to do so. 

  

	(b)	Rights in [...***...] the following [...***...] rights: 


 

	 	(1)	[...***...] rights. The Government shall [...***...] rights in [...***...] that are – 


 

	 	(i)	[...***...] which have been or will be [...***...]; 

  

	 	(ii)	[...***...] for this contract, when the [...***...]. 

  

	(c)	Specifics. The Contractor and the Government agree to the following: 


 

	 	(1)	The [...***...] shall reside with the subcontractor – [...***...]. 


 

	 	(2)	The [...***...] rights conveyed to the U.S. Government, under this contract, does not [...***...]. 


 

 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page 
 16
 of 35
  


	 	(3)	Copies of the collection, as defined under section (a) of this clause, will be made available to U.S. Government agencies, to include Department of Defense, upon
request. 

  

	 	(4)	The [...***...] prior to execution of this contract [...***...]. 


 

	 	(5)	Upon completion of the contract, the collection – as defined under section (a) of this clause – [...***...] the U.S. Government.


 End clause 

H.1 PATENT RIGHTS 
 RETENTION BY THE
CONTRACTOR 
 In accordance with FAR 52.227-11(f), reporting on utilization of subject inventions: 

The Contractor agrees to submit, periodic reports annually on the utilization of a subject invention or efforts at obtaining such utilization that are
being made by the Contractor or its licensees or assignees. 
 INDIRECT COST RATES CEILING In accordance with FAR 42.707(c) (1) (2),
reimbursement for indirect costs under this contract shall be at billing rates but not in excess of the following negotiated ceiling rates: 

2010: 
 Fringe: [...***...] 

G&A: [...***...] 
 M&S Handling:
[...***...] 
 Overhead: [...***...] 

2011: 
 Fringe: [...***...] 

G&A: [...***...] 
 M&S Handling:
[...***...] 
 Overhead: [...***...] 

2012: 
 Fringe: [...***...] 

 

 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page 
 17
 of 35
  

 G&A: [...***...] 

M&S Handling: [...***...] 
 Overhead:
[...***...] 
 2013: 
 Fringe:
[...***...] 
 G&A: [...***...] 

M&S Handling: [...***...] 
 Overhead:
[...***...] 
 2014: 
 Fringe:
[...***...] 
 G&A: [...***...] 

M&S Handling: [...***...] 
 Overhead:
[...***...] 
 The Government will not be obligated to pay any additional amount should the final indirect cost rates exceed the
negotiated ceiling rates. In the event the final indirect cost rates are less than the negotiated ceiling rates, the negotiated rates will be reduced to conform to the lower rates. 

POST AWARD AUDIT 
 IAW FAR Part 42.102 A
Post Award audit will be requested, by the Contracting Officer, 6 months after award of contract. The audit will include indirect rates, review of the contractor’s accounting system, and review of the contractor’s purchasing system. Any
and all capped rates shall become final indirect rates upon rate approval by DCAA. 
 Upon receipt of negative findings from DCAA, the
government may elect to terminate the contract pursuant to FAR 52.249-6 or they may elect to re-open negotiations for downward adjustments of indirect rates, if required. 
  


 ***Confidential Treatment Requested 









 HDTRA1-10-C-004 

 Page 
 18
 of 35 
  

 Section I - Contract Clauses 

CLAUSES INCORPORATED BY REFERENCE 
  

					
	52.202-1	  	Definitions	  	JUL 2004
	52.203-3	  	Gratuities	  	APR 1984
	52.203-5	  	Covenant Against Contingent Fees	  	APR 1984
	52.203-6	  	Restrictions On Subcontractor Sales To The Government	  	SEP 2006
	52.203-7	  	Anti-Kickback Procedures	  	JUL 1995
	52.203-8	  	Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity	  	JAN 1997
	52.203-10	  	Price Or Fee Adjustment For Illegal Or Improper Activity	  	JAN 1997
	52.203-12	  	Limitation On Payments To Influence Certain Federal Transactions	  	SEP 2007
	52.203-13	  	Contractor Code of Business Ethics and Conduct	  	DEC 2008
	52.203-14	  	Display of Hotline Poster(s)	  	DEC 2007
	52.204-4	  	Printed or Copied Double-Sided on Recycled Paper	  	AUG 2000
	52.204-7	  	Central Contractor Registration	  	APR 2008
	52.209-6	  	Protecting the Government’s Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment	  	SEP 2006
	52.215-2	  	Audit and Records—Negotiation	  	MAR 2009
	52.215-8	  	Order of Precedence—Uniform Contract Format	  	OCT 1997
	52.215-10	  	Price Reduction for Defective Cost or Pricing Data	  	OCT 1997
	52.215-12	  	Subcontractor Cost or Pricing Data	  	OCT 1997
	52.215-15	  	Pension Adjustments and Asset Reversions	  	OCT 2004
	52.215-17	  	Waiver of Facilities Capital Cost of Money	  	OCT 1997
	52.215-18	  	Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other than Pensions	  	JUL 2005
	52.215-19	  	Notification of Ownership Changes	  	OCT 1997
	52.215-21	  	Requirements for Cost or Pricing Data or Information Other Than Cost or Pricing Data—Modifications	  	OCT 1997
	52.215-23	  	Limitations on Pass-Through Charges	  	OCT 2009
	52.216-7	  	Allowable Cost And Payment	  	DEC 2002
	52.216-8	  	Fixed Fee	  	MAR 1997
	52.219-8	  	Utilization of Small Business Concerns	  	MAY 2004
	52.222-3	  	Convict Labor	  	JUN 2003
	52.222-21	  	Prohibition Of Segregated Facilities	  	FEB 1999
	52.222-26	  	Equal Opportunity	  	MAR 2007
	52.222-35	  	Equal Opportunity For Special Disabled Veterans, Veterans of the Vietnam Era, and Other Eligible Veterans	  	SEP 2006
	52.222-36	  	Affirmative Action For Workers With Disabilities	  	JUN 1998
	52.222-37	  	Employment Reports On Special Disabled Veterans, Veterans Of The Vietnam Era, and Other Eligible Veterans	  	SEP 2006
	52.222-50	  	Combating Trafficking in Persons	  	FEB 2009
	52.222-54	  	Employment Eligibility Verification	  	JAN 2009
	52.223-6	  	Drug-Free Workplace	  	MAY 2001
	52.223-14	  	Toxic Chemical Release Reporting	  	AUG 2003
	52.225-13	  	Restrictions on Certain Foreign Purchases	  	JUN 2008
	52.227-1	  	Authorization and Consent	  	DEC 2007
	52.227-1 Alt I	  	Authorization And Consent (Dec 2007) - Alternate I	  	APR 1984
	52.227-2	  	Notice And Assistance Regarding Patent And Copyright Infringement	  	DEC 2007
	52.227-11	  	Patent Rights—Ownership By The Contractor	  	DEC 2007









 HDTRA1-10-C-004 

 Page 
 19
 of 35 
  


					
	52.227-11 Alt II	  	Patent Rights—Ownership by the Contractor (Dec 2007) – Alternate II	  	DEC 2007
	52.228-7	  	Insurance—Liability To Third Persons	  	MAR 1996
	52.229-10	  	State of New Mexico Gross Receipts and Compensating Tax	  	APR 2003
	52.232-9	  	Limitation On Withholding Of Payments	  	APR 1984
	52.232-17	  	Interest	  	OCT 2008
	52.232-23	  	Assignment Of Claims	  	JAN 1986
	52.232-23 Alt I	  	Assignment of Claims (Jan 1986) -Alternate I	  	APR 1984
	52.232-25	  	Prompt Payment	  	OCT 2008
	52.232-25 Alt I	  	Prompt Payment (Oct 2008) Alternate I	  	FEB 2002
	52.232-33	  	Payment by Electronic Funds Transfer—Central Contractor	  	OCT 2003
	52.233-1	  	Disputes	  	JUL 2002
	52.233-1 Alt I	  	Disputes (Jul 2002) - Alternate I	  	DEC 1991
	52.233-3	  	Protest After Award	  	AUG 1996
	52.233-3 Alt I	  	Protest After Award (Aug 1996) - Alternate I	  	JUN 1985
	52.233-4	  	Applicable Law for Breach of Contract Claim	  	OCT 2004
	52.242-1	  	Notice of Intent to Disallow Costs	  	APR 1984
	52.242-3	  	Penalties for Unallowable Costs	  	MAY 2001
	52.242-4	  	Certification of Final Indirect Costs	  	JAN 1997
	52.242-13	  	Bankruptcy	  	JUL 1995
	52.243-2	  	Changes—Cost-Reimbursement	  	AUG 1987
	52.243-2 Alt V	  	Changes—Cost-Reimbursement (Aug 1987) - Alternate V	  	APR 1984
	52.244-2	  	Subcontracts	  	JUN 2007
	52.244-5	  	Competition In Subcontracting	  	DEC 1996
	52.244-6	  	Subcontracts for Commercial Items	  	AUG 2009
	52.245-1	  	Government Property	  	JUN 2007
	52.245-1 (Dev)	  	Government Property (June 2007)	  	JUN 2007
	52.245-9	  	Use And Charges	  	JUN 2007
	52.246-25	  	Limitation Of Liability—Services	  	FEB 1997
	52.249-6	  	Termination (Cost Reimbursement)	  	MAY 2004
	52.249-14	  	Excusable Delays	  	APR 1984
	52.251-1	  	Government Supply Sources	  	APR 1984
	52.253-1	  	Computer Generated Forms	  	JAN 1991
	252.201-7000	  	Contracting Officer’s Representative	  	DEC 1991
	252.203-7000	  	Requirements Relating to Compensation of Former DoD Officials	  	JAN 2009
	252.203-7001	  	Prohibition On Persons Convicted of Fraud or Other Defense-Contract-Related Felonies	  	DEC 2008
	252.203-7002	  	Requirement to Inform Employees of Whistleblower Rights	  	JAN 2009
	252.204-7000	  	Disclosure Of Information	  	DEC 1991
	252.204-7003	  	Control Of Government Personnel Work Product	  	APR 1992
	252.204-7004 Alt A	  	Central Contractor Registration (52.204-7) Alternate A	  	SEP 2007
	252.204-7009	  	Requirements Regarding Potential Access to Export-Controlled Items	  	JUL 2008
	252.205-7000	  	Provision Of Information To Cooperative Agreement Holders	  	DEC 1991
	252.209-7004	  	Subcontracting With Firms That Are Owned or Controlled By The Government of a Terrorist Country	  	DEC 2006
	252.211-7003	  	Item Identification and Valuation	  	AUG 2008
	252.211-7007	  	Reporting of Government-Furnished Equipment in the DoD Item Unique Identification (IUID) Registry	  	NOV 2008
	252.215-7000	  	Pricing Adjustments	  	DEC 1991
	252.215-7002	  	Cost Estimating System Requirements	  	DEC 2006









 HDTRA1-10-C-004 

 Page 
 20
 of 35 
  


					
	252.222-7999 (Dev)	  	Additional Requirements and Responsibilities Restricting the Use of Mandatory Arbitration Agreements (Deviation)	  	FEB 2010
	252.225-7004	  	Report of Intended Performance Outside the United States and Canada—Submission after Award	  	MAY 2007
	252.225-7006	  	Quarterly Reporting of Actual Contract Performance Outside the United States	  	MAY 2007
	252.225-7012	  	Preference For Certain Domestic Commodities	  	DEC 2008
	252.226-7001	  	Utilization of Indian Organizations and Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns	  	SEP 2004
	252.227-7013	  	Rights in Technical Data—Noncommercial Items	  	NOV 1995
	252.227-7016	  	Rights in Bid or Proposal Information	  	JUN 1995
	252.227-7025	  	Limitations on the Use or Disclosure of Government-Furnished Information Marked with Restrictive Legends	  	JUN 1995
	252.227-7027	  	Deferred Ordering Of Technical Data Or Computer Software	  	APR 1988
	252.227-7030	  	Technical Data—Withholding Of Payment	  	MAR 2000
	252.227-7037	  	Validation of Restrictive Markings on Technical Data	  	SEP 1999
	252.227-7039	  	Patents—Reporting Of Subject Inventions	  	APR 1990
	252.231-7000	  	Supplemental Cost Principles	  	DEC 1991
	252.232-7003	  	Electronic Submission of Payment Requests and Receiving Reports	  	MAR 2008
	252.232-7010	  	Levies on Contract Payments	  	DEC 2006
	252.235-7002	  	Animal Welfare	  	DEC 1991
	252.235-7010	  	Acknowledgment of Support and Disclaimer	  	MAY 1995
	252.235-7011	  	Final Scientific or Technical Report	  	NOV 2004
	252.243-7002	  	Requests for Equitable Adjustment	  	MAR 1998
	252.244-7000	  	Subcontracts for Commercial Items and Commercial Components (DoD Contracts)	  	AUG 2009
	252.247-7023	  	Transportation of Supplies by Sea	  	MAY 2002
	252.247-7024	  	Notification Of Transportation Of Supplies By Sea	  	MAR 2000
	252.251-7000	  	Ordering From Government Supply Sources	  	NOV 2004

 CLAUSES INCORPORATED BY FULL TEXT 

 

	52.216-7	ALLOWABLE COST AND PAYMENT (DEC 2002) 

 (a)
Invoicing. 
 (1) The Government will make payments to the Contractor when requested as work progresses, but (except for small business
concerns) not more often than once every 2 weeks, in amounts determined to be allowable by the Contracting Officer in accordance with Federal Acquisition Regulation (FAR) subpart 31.2 in effect on the date of this contract and the terms of this
contract. The Contractor may submit to an authorized representative of the Contracting Officer, in such form and reasonable detail as the representative may require, an invoice or voucher supported by a statement of the claimed allowable cost for
performing this contract. 
 (2) Contract financing payments are not subject to the interest penalty provisions of the Prompt Payment Act.
Interim payments made prior to the final payment under the contract are contract financing payments, except interim payments if this contract contains Alternate I to the clause at 52.232-25. 

(3) The designated payment office will make interim payments for contract financing on the 30th day after the designated billing office receives a proper
payment request. 








 HDTRA1-10-C-004 

 Page 
 21
 of 35 
  

 In the event that the Government requires an audit or other review of a specific payment request to
ensure compliance with the terms and conditions of the contract, the designated payment office is not compelled to make payment by the specified due date. 

(b) Reimbursing costs. (1) For the purpose of reimbursing allowable costs (except as provided in subparagraph (b)(2) of the clause, with respect to
pension, deferred profit sharing, and employee stock ownership plan contributions), the term “costs” includes only— 
 (i) Those
recorded costs that, at the time of the request for reimbursement, the Contractor has paid by cash, check, or other form of actual payment for items or services purchased directly for the contract; 

(ii) When the Contractor is not delinquent in paying costs of contract performance in the ordinary course of business, costs incurred, but not
necessarily paid, for— 
 (A) Supplies and services purchased directly for the contract and associated financing payments to
subcontractors, provided payments determined due will be made— 
 (1) In accordance with the terms and conditions of a subcontract or
invoice; and 
 (2) Ordinarily within 30 days of the submission of the Contractor’s payment request to the Government; 

(B) Materials issued from the Contractor’s inventory and placed in the production process for use on the contract; 

(C) Direct labor; 
 (D) Direct travel;

 (E) Other direct in-house costs; and 

(F) Properly allocable and allowable indirect costs, as shown in the records maintained by the Contractor for purposes of obtaining reimbursement under
Government contracts; and 
 (iii) The amount of financing payments that have been paid by cash, check, or other forms of payment to
subcontractors. 
 (2) Accrued costs of Contractor contributions under employee pension plans shall be excluded until actually paid unless—

 (i) The Contractor’s practice is to make contributions to the retirement fund quarterly or more frequently; and 

(ii) The contribution does not remain unpaid 30 days after the end of the applicable quarter or shorter payment period (any contribution remaining unpaid
shall be excluded from the Contractor’s indirect costs for payment purposes). 
 (3) Notwithstanding the audit and adjustment of invoices
or vouchers under paragraph (g) of this clause, allowable indirect costs under this contract shall be obtained by applying indirect cost rates established in accordance with paragraph (d) of this clause. 

(4) Any statements in specifications or other documents incorporated in this contract by reference designating performance of services or furnishing of
materials at the Contractor’s expense or at no cost to the Government shall be disregarded for purposes of cost-reimbursement under this clause. 

(c) Small business concerns. A small business concern may receive more frequent payments than every 2 weeks. 








 HDTRA1-10-C-004 

 Page
 22
 of 35 
  

 (d) Final indirect cost rates. (1) Final annual indirect cost rates and the appropriate bases shall
be established in accordance with Subpart 42.7 of the Federal Acquisition Regulation (FAR) in effect for the period covered by the indirect cost rate proposal. 

(2)(i) The Contractor shall submit an adequate final indirect cost rate proposal to the Contracting Officer (or cognizant Federal agency official) and
auditor within the 6-month period following the expiration of each of its fiscal years. Reasonable extensions, for exceptional circumstances only, may be requested in writing by the Contractor and granted in writing by the Contracting Officer. The
Contractor shall support its proposal with adequate supporting data. 
 (ii) The proposed rates shall be based on the Contractor’s actual
cost experience for that period. The appropriate Government representative and the Contractor shall establish the final indirect cost rates as promptly as practical after receipt of the Contractor’s proposal. 

(3) The Contractor and the appropriate Government representative shall execute a written understanding setting forth the final indirect cost rates. The
understanding shall specify (i) the agreed-upon final annual indirect cost rates, 
 (ii) the bases to which the rates apply,
(iii) the periods for which the rates apply, (iv) any specific indirect cost items treated as direct costs in the settlement, and (v) the affected contract and/or subcontract, identifying any with advance agreements or special terms
and the applicable rates. The understanding shall not change any monetary ceiling, contract obligation, or specific cost allowance or disallowance provided for in this contract. The understanding is incorporated into this contract upon execution.

 (4) Failure by the parties to agree on a final annual indirect cost rate shall be a dispute within the meaning of the Disputes clause.

 (5) Within 120 days (or longer period if approved in writing by the Contracting Officer) after settlement of the final annual indirect cost
rates for all years of a physically complete contract, the Contractor shall submit a completion invoice or voucher to reflect the settled amounts and rates. 

(6)(i) If the Contractor fails to submit a completion invoice or voucher within the time specified in paragraph (d)(5) of this clause, the Contracting
Officer may— 
 (A) Determine the amounts due to the Contractor under the contract; and 

(B) Record this determination in a unilateral modification to the contract. 

(ii) This determination constitutes the final decision of the Contracting Officer in accordance with the Disputes clause. 

(e) Billing rates. Until final annual indirect cost rates are established for any period, the Government shall reimburse the Contractor at billing rates
established by the Contracting Officer or by an authorized representative (the cognizant auditor), subject to adjustment when the final rates are established. These billing rates— 

(1) Shall be the anticipated final rates; and 

(2) May be prospectively or retroactively revised by mutual agreement, at either party’s request, to prevent substantial overpayment or
underpayment. 
 (f) Quick-closeout procedures. Quick-closeout procedures are applicable when the conditions in FAR 42.708(a) are satisfied.

 (g) Audit. At any time or times before final payment, the Contracting Officer may have the Contractor’s invoices or vouchers and
statements of cost audited. Any payment may be (1) Reduced by amounts found by the Contracting Officer not to constitute allowable costs or (2) Adjusted for prior overpayments or underpayments. 








 HDTRA1-10-C-004 

 Page
 23
 of 35 
  

 (h) Final payment. (1) Upon approval of a completion invoice or voucher submitted by the Contractor
in accordance with paragraph (d)(4) of this clause, and upon the Contractor’s compliance with all terms of this contract, the Government shall promptly pay any balance of allowable costs and that part of the fee (if any) not previously paid.

 (2) The Contractor shall pay to the Government any refunds, rebates, credits, or other amounts (including interest, if any) accruing to or
received by the Contractor or any assignee under this contract, to the extent that those amounts are properly allocable to costs for which the Contractor has been reimbursed by the Government. Reasonable expenses incurred by the Contractor for
securing refunds, rebates, credits, or other amounts shall be allowable costs if approved by the Contracting Officer. Before final payment under this contract, the Contractor and each assignee whose assignment is in effect at the time of final
payment shall execute and deliver— 
 (i) An assignment to the Government, in form and substance satisfactory to the Contracting Officer,
of refunds, rebates, credits, or other amounts (including interest, if any) properly allocable to costs for which the Contractor has been reimbursed by the Government under this contract; and 

(ii) A release discharging the Government, its officers, agents, and employees from all liabilities, obligations, and claims arising out of or under this
contract, except— 
 (A) Specified claims stated in exact amounts, or in estimated amounts when the exact amounts are not known;

 (B) Claims (including reasonable incidental expenses) based upon liabilities of the Contractor to third parties arising out of the
performance of this contract; provided, that the claims are not known to the Contractor on the date of the execution of the release, and that the Contractor gives notice of the claims in writing to the Contracting Officer within 6 years following
the release date or notice of final payment date, whichever is earlier; and 
 (C) Claims for reimbursement of costs, including reasonable
incidental expenses, incurred by the Contractor under the patent clauses of this contract, excluding, however, any expenses arising from the Contractor’s indemnification of the Government against patent liability. 

(End of clause) 
 CLAUSES INCORPORATED BY FULL
TEXT 
  

	52.217-8	OPTION TO EXTEND SERVICES (NOV 1999) 

 The
Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The
option provision may be exercised more than once, but the total extension of performance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor up to end of period of performance.

 (End of clause) 
 CLAUSES
INCORPORATED BY FULL TEXT 
  

	52.217-9	OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000) 


(a) The Government may extend the term of this contract by written notice to the Contractor prior to end of period of performance; provided that the
Government gives the Contractor a preliminary written notice of its intent to extend at least 30 days before the contract expires. The preliminary notice does not commit the Government to an extension. 








 HDTRA1-10-C-004 

 Page
 24
 of 35 
  

 (b) If the Government exercises this option, the extended contract shall be considered to include this
option clause. 
 (c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 60 months.

 (d) Option Task 4.1 shall be exercised no later than 30 days after demonstration of Proof of Principle (POP) and POP Milestone Report
submission. 
 CLAUSES INCORPORATED BY FULL TEXT 
  

	52.219-28	POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (APR 2009) 


(a) Definitions. As used in this clause— 

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five
years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority. 

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in
which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is “not dominant in its field of operation”
when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all
appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of
business activity. 
 (b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor
shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following: 

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation
agreement was executed prior to inclusion of this clause in the contract. 
 (2) Within 30 days after a merger or acquisition that does not
require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract. 

(3) For long-term contracts— 
 (i) Within
60 to 120 days prior to the end of the fifth year of the contract; and 
 (ii) Within 60 to 120 days prior to the date specified in the contract
for exercising any option thereafter. 
 (c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at
the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at
http://www.sba.gov/services/contractingopportunities/sizestandardstopics/. 








 HDTRA1-10-C-004 

 Page
 25
 of 35 
  

 (d) The small business size standard for a Contractor providing a product which it does not manufacture
itself, for a contract other than a construction or service contract, is 500 employees. 
 (e) Except as provided in paragraph (g) of this
clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central
Contractor Registration, as necessary, to ensure that they reflect the Contractor’s current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data
have been validated or updated, and provide the date of the validation or update. 
 (f) If the Contractor represented that it was other than a
small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause. 

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable
to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed: 

The Contractor represents that it ( X ) is, ( ) is not a small business concern under NAICS Code 541711- assigned to contract number HDTRA1-10-C-0004.

 (Contractor to sign and date and insert authorized signer’s name and title). 

(End of clause) 
 CLAUSES INCORPORATED BY FULL
TEXT 
  

	52.222-2	PAYMENT FOR OVERTIME PREMIUMS (JUL 1990) 

 (a)
The use of overtime is authorized under this contract if the overtime premium cost does not exceed 0.00 or the overtime premium is paid for work — 

(1) Necessary to cope with emergencies such as those resulting from accidents, natural disasters, breakdowns of production equipment, or occasional
production bottlenecks of a sporadic nature; 
 (2) By indirect-labor employees such as those performing duties in connection with
administration, protection, transportation, maintenance, standby plant protection, operation of utilities, or accounting; 
 (3) To perform
tests, industrial processes, laboratory procedures, loading or unloading of transportation conveyances, and operations in flight or afloat that are continuous in nature and cannot reasonably be interrupted or completed otherwise; or 

(4) That will result in lower overall costs to the Government. 

(b) Any request for estimated overtime premiums that exceeds the amount specified above shall include all estimated overtime for contract completion and
shall— 
 (1) Identify the work unit; e.g., department or section in which the requested overtime will be used, together with present
workload, staffing, and other data of the affected unit sufficient to permit the Contracting Officer to evaluate the necessity for the overtime; 








 HDTRA1-10-C-004 

 Page
 26
 of 35 
  

 (2) Demonstrate the effect that denial of the request will have on the contract delivery or performance
schedule; 
 (3) Identify the extent to which approval of overtime would affect the performance or payments in connection with other Government
contracts, together with identification of each affected contract; and 
 (4) Provide reasons why the required work cannot be performed by using
multishift operations or by employing additional personnel. 
  

	*	Insert either “zero” or the dollar amount agreed to during negotiations. The inserted figure does not apply to the exceptions in paragraph (a)(1) through
(a)(4) of the clause. 

 (End of clause) 
  

	52.232-22	LIMITATION OF FUNDS (APR 1984) 

 (a) The parties
estimate that performance of this contract will not cost the Government more than (1) the estimated cost specified in the Schedule or, (2) if this is a cost-sharing contract, the Government’s share of the estimated cost specified in
the Schedule. The Contractor agrees to use its best efforts to perform the work specified in the Schedule and all obligations under this contract within the estimated cost, which, if this is a cost-sharing contract, includes both the
Government’s and the Contractor’s share of the cost. 
 (b) The Schedule specifies the amount presently available for payment by the
Government and allotted to this contract, the items covered, the Government’s share of the cost if this is a cost-sharing contract, and the period of performance it is estimated the allotted amount will cover. The parties contemplate that the
Government will allot additional funds incrementally to the contract up to the full estimated cost to the Government specified in the Schedule, exclusive of any fee. The Contractor agrees to perform, or have performed, work on the contract up to the
point at which the total amount paid and payable by the Government under the contract approximates but does not exceed the total amount actually allotted by the Government to the contract. 

(c) The Contractor shall notify the Contracting Officer in writing whenever it has reason to believe that the costs it expects to incur under this
contract in the next 60 days, when added to all costs previously incurred, will exceed 75 percent of (1) the total amount so far allotted to the contract by the Government or, (2) if this is a cost-sharing contract, the amount then
allotted to the contract by the Government plus the Contractor’s corresponding share. The notice shall state the estimated amount of additional funds required to continue performance for the period specified in the Schedule. 

(d) Sixty days before the end of the period specified in the Schedule, the Contractor shall notify the Contracting Officer in writing of the estimated
amount of additional funds, if any, required to continue timely performance under the contract or for any further period specified in the Schedule or otherwise agreed upon, and when the funds will be required. 

(e) If, after notification, additional funds are not allotted by the end of the period specified in the Schedule or another agreed-upon date, upon the
Contractor’s written request the Contracting Officer will terminate this contract on that date in accordance with the provisions of the Termination clause of this contract. If the Contractor estimates that the funds available will allow it to
continue to discharge its obligations beyond that date, it may specify a later date in its request, and the Contracting Officer may terminate this contract on that later date. 

(f) Except as required by other provisions of this contract, specifically citing and stated to be an exception to this clause— 

(1) The Government is not obligated to reimburse the Contractor for costs incurred in excess of the total amount allotted by the Government to this
contract; and 








 HDTRA1-10-C-004 

 Page
 27
 of 35 
  

 (2) The Contractor is not obligated to continue performance under this contract (including actions under
the Termination clause of this contract) or otherwise incur costs in excess of (i) the amount then allotted to the contract by the Government or, (ii) if this is a cost-sharing contract, the amount then allotted by the Government to the
contract plus the Contractor’s corresponding share, until the Contracting Officer notifies the Contractor in writing that the amount allotted by the Government has been increased and specifies an increased amount, which shall then constitute
the total amount allotted by the Government to this contract. 
 (g) The estimated cost shall be increased to the extent that (1) the
amount allotted by the Government or, (2) if this is a cost-sharing contract, the amount then allotted by the Government to the contract plus the Contractor’s corresponding share, exceeds the estimated cost specified in the Schedule. If
this is a cost-sharing contract, the increase shall be allocated in accordance with the formula specified in the Schedule. 
 (h) No notice,
communication, or representation in any form other than that specified in subparagraph (f)(2) above, or from any person other than the Contracting Officer, shall affect the amount allotted by the Government to this contract. In the absence of the
specified notice, the Government is not obligated to reimburse the Contractor for any costs in excess of the total amount allotted by the Government to this contract, whether incurred during the course of the contract or as a result of termination.

 (i) When and to the extent that the amount allotted by the Government to the contract is increased, any costs the Contractor incurs before
the increase that are in excess of (1) the amount previously allotted by the Government or, 
 (2) if this is a cost-sharing contract, the
amount previously allotted by the Government to the contract plus the Contractor’s corresponding share, shall be allowable to the same extent as if incurred afterward, unless the Contracting Officer issues a termination or other notice and
directs that the increase is solely to cover termination or other specified expenses. 
 (j) Change orders shall not be considered an
authorization to exceed the amount allotted by the Government specified in the Schedule, unless they contain a statement increasing the amount allotted. 

(k) Nothing in this clause shall affect the right of the Government to terminate this contract. If this contract is terminated, the Government and the
Contractor shall negotiate an equitable distribution of all property produced or purchased under the contract, based upon the share of costs incurred by each. 

(l) If the Government does not allot sufficient funds to allow completion of the work, the Contractor is entitled to a percentage of the fee specified in
the Schedule equalling the percentage of completion of the work contemplated by this contract. 
 (End of clause) 

 

	52.243-7	NOTIFICATION OF CHANGES (APR 1984) 

 (a)
Definitions. 
 “Contracting Officer,” as used in this clause, does not include any representative of the Contracting Officer.

 “Specifically authorized representative (SAR),” as used in this clause, means any person the Contracting Officer has so designated
by written notice (a copy of which shall be provided to the Contractor) which shall refer to this subparagraph and shall be issued to the designated representative before the SAR exercises such authority. 

(b) Notice. The primary purpose of this clause is to obtain prompt reporting of Government conduct that the Contractor considers to constitute a change
to this contract. Except for changes identified as such in writing and 








 HDTRA1-10-C-004 

 Page
 28
 of 35 
  

 
signed by the Contracting Officer, the Contractor shall notify the Administrative Contracting Officer in writing, within 15 calendar days from the date that the Contractor identifies any
Government conduct (including actions, inactions, and written or oral communications) that the Contractor regards as a change to the contract terms and conditions. On the basis of the most accurate information available to the Contractor, the notice
shall state— 
 (1) The date, nature, and circumstances of the conduct regarded as a change; 

(2) The name, function, and activity of each Government individual and Contractor official or employee involved in or knowledgeable about such conduct;

 (3) The identification of any documents and the substance of any oral communication involved in such conduct; 

(4) In the instance of alleged acceleration of scheduled performance or delivery, the basis upon which it arose; 

(5) The particular elements of contract performance for which the Contractor may seek an equitable adjustment under this clause, including- 

(i) What contract line items have been or may be affected by the alleged change; 

(ii) What labor or materials or both have been or may be added, deleted, or wasted by the alleged change; 

(iii) To the extent practicable, what delay and disruption in the manner and sequence of performance and effect on continued performance have been or may
be caused by the alleged change; 
 (iv) What adjustments to contract price, delivery schedule, and other provisions affected by the alleged
change are estimated; and 
 (6) The Contractor’s estimate of the time by which the Government must respond to the Contractor’s notice
to minimize cost, delay or disruption of performance. 
 (c) Continued performance. Following submission of the notice required by
(b) above, the Contractor shall diligently continue performance of this contract to the maximum extent possible in accordance with its terms and conditions as construed by the Contractor, unless the notice reports a direction of the Contracting
Officer or a communication from a SAR of the Contracting Officer, in either of which events the Contractor shall continue performance; provided, however, that if the Contractor regards the direction or communication as a change as described in
(b) above, notice shall be given in the manner provided. All directions, communications, interpretations, orders and similar actions of the SAR shall be reduced to writing and copies furnished to the Contractor and to the Contracting Officer.
The Contracting Officer shall countermand any action which exceeds the authority of the SAR. 
 (d) Government response. The Contracting Officer
shall promptly, within 30 calendar days after receipt of notice, respond to the notice in writing. In responding, the Contracting Officer shall either— 

(1) Confirm that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance;

 (2) Countermand any communication regarded as a change; 

(3) Deny that the conduct of which the Contractor gave notice constitutes a change and when necessary direct the mode of further performance; or

 (4) In the event the Contractor’s notice information is inadequate to make a decision under (1), (2), or (3) above, advise the
Contractor what additional information is required, and establish the date by which it should be furnished and the date thereafter by which the Government will respond. 








 HDTRA1-10-C-004 

 Page
 29
 of 35 
  

 (e) Equitable adjustments. 

(1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or
decrease in the Contractor’s cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made— 

(i) In the contract price or delivery schedule or both; and 

(ii) In such other provisions of the contract as may be affected. 

(2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the
Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor
identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting
Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor’s failure to provide notice or to
continue performance as provided, respectively, in (b) and (c) above. 
 Note: The phrases “contract price” and
“cost” wherever they appear in the clause, may be appropriately modified to apply to cost-reimbursement or incentive contracts, or to combinations thereof. 

(End of clause) 
  

			
	 52.252-2
	  	CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

 This contract
incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed
electronically at this/these address(es): 
 http://farsite.hill.af.mil 

(End of clause) 
  

			
	 52.252-6
	  	AUTHORIZED DEVIATIONS IN CLAUSES (APR 1984)

 (a) The use in
this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause. 

(b) The use in this solicitation or contract of any Defense Federal Acquisition Regulations Supplement (48 CFR Chapter 2) clause with an
authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation. 
 (End of clause) 








 HDTRA1-10-C-004 

 Page
 30
 of 35 
  


			
	 252.201-9003
	  	LIMITATION OF AUTHORITY (JUN 2009)

 No person in the
Government, other than a Contracting Officer, has the authority to provide direction to the Contractor, which alters the Contractor’s obligations or changes this contract in any way. If any person representing the Government, other than a
Contracting Officer, attempts to alter contract obligations, change the contract specifications/statement of work or tells the contractor to perform some effort which the Contractor believes to be outside the scope of this contract, the Contractor
shall immediately notify the Procuring Contracting Officer (PCO). Contractor personnel shall not comply with any order or direction which they believe to be outside the scope of this contract unless the order or direction is issued by a Contracting
Officer. 
  

			
	 252.203-9004
	  	ETIOLOGIC AGENTS—BIOLOGICAL DEFENSE RESEARCH PROGRAM (FEB 2008)

  

	 	a.	For purpose of this contract etiologic agent—biological defense program is defined as: any viable microorganism, or its toxin which causes or may cause human
disease, including those agents listed in 42 CFR 73, 9 CFR 121, and 7 CFR 331, of the Department of Health and Human Services and Department of Agriculture regulations, respectively, and any agent of biological origin that poses a degree of hazard
to those agents and is further identified by the US Army. The contractor shall comply with the following when working with etiologic agents: 

  

	 	(1)	29 Code of Federal Regulations 1910, Occupational Health and Safety; 

  

	 	(2)	US Department of Health and Human Services (DHHS) and US Department of Agriculture, Select Agent Program(s), 42 CFR 73, 9 CFR 121, and 7 CFR 331; and


  

	 	(3)	DHHS Publication No. 93-8395, Biosafety in Microbiological and Biomedical Laboratories, latest edition. 


 

	 	b.	Etiologic agents shall be packaged, labeled, shipped, and transported in accordance with applicable Federal, State, and local laws and regulations, to include:


  

	 	(1)	42 CFR 72 (Interstate Shipment of Etiologic Agents); 

  

	 	(2)	49 CFR 172 and 173 (Department of Transportation); 

  

	 	(3)	9 CFR 122 (USDA Restricted Animal Pathogens); 

  

	 	(4)	International Air Transport Association Dangerous Goods Regulations; 

  

	 	(5)	The United States Postal Service shall not be used for transportation of BDRP related etiologic agents; and 


 

	 	(6)	If performance is outside of the United States, any additional procedures required by the nation where the work is to be performed. 


252.203-9005, Implementation of Contractor Code of Business Ethics and Conduct (Dec 2008) 

In accordance with FAR clause 52.203-13, Contractor Code of Business Ethics and Conduct, the designated “agency Office of the Inspector General”
is the DoD OIG at the following address: 
 Office of the Inspector General 

United States Department of Defense 

Investigative Policy and Oversight 








 HDTRA1-10-C-004 

 Page
 31
 of 35 
  

 Contractor Disclosure Program 

400 Army Navy Drive, Suite 1037 

Arlington, VA 22202-4704 

Toll Free Telephone: 866-429-8011 
  

			
	 252.204-9004
	  	IMPLEMENTATION OF DISCLOSURE OF INFORMATION (JUN 2007)

 In
accordance with DFARS 252.204-7000 Disclosure of Information, any information to be released shall be submitted at least 45 days before the proposed release date, for security and policy review. Submit one copy to each below: 

(a) Office of Public Affairs, DTRA/DIR/COS/PA, 8725 John J. Kingman Dr, MS 6201, Ft Belvoir VA 22060-6201. 

(b) Contracting Officer 

(c) Program Manager 

(d) Task Order Manager 

(End of Clause) 
  

			
	 252.209-9002
	  	NON-GOVERNMENT SUPPORT PERSONNEL (JAN 2008)

 The
following companies may have access to contractor information, technical data or computer software that may be marked as proprietary or otherwise marked with restrictive legends: Suntiva LLC (Formerly C-Systems International Corporation )(contract
specialist support); Systems Research and Analysis (SRA, managing JPRAS) and The Tauri Group (Advisory and Assistance Services). Each contract contains organizational conflict of interest provisions and/or includes contractual requirements for
non-disclosure of proprietary contractor information or data/software marked with restrictive legends. The contractor, by submitting a proposal or entering into this contract, is deemed to have consented to the disclosure of its information to
Suntiva LLC, SRA and The Tauri Group under the conditions and limitations described herein. 
  

			
	 252.215-9004
	  	KEY PERSONNEL (FEB 2000)

 The personnel listed below are
considered essential to the work being performed hereunder. Prior to removing, replacing, or diverting any of the specified individuals, the Contractor shall notify the Contracting Officer reasonably in advance and shall submit justification
(including proposed substitutions) in sufficient detail to permit evaluation of the impact on this Contract. No deviation shall be made by the Contractor without the prior written consent of the Contracting Officer; provided, that the Contracting
Officer may ratify in writing the change, such ratification shall constitute the consent of the Contracting Officer required by this paragraph. The personnel listed below may, with the consent of the contracting parties, be amended from time to time
during the course of the Contract to either add or delete personnel as appropriate. 
 Principal Investigator 








 HDTRA1-10-C-004 

 Page
 32
 of 35 
  


			
	 252.216-9003
	  	CONSULTANTS (OCT 1998)

 Services of consultants shall be at
rates and for periods approved in advance by the Contracting Officer. Requests for approval shall be submitted to the Contracting Officer sufficiently in advance of the need to use a consultant under this Contract. The request shall include
(a) a copy of the proposed consultant agreement, (b) a brief biography of the consultant, and (c) an indication of the area(s) in which consultant’s expertise will be utilized and why it is essential for contract performance. In
addition, significant deviations from the dollar amount approved for consultant services, or changes in the consultants to be utilized, must likewise be approved in advance upon submission of adequate justification. 

 

			
	 252.227-9000
	  	COMPUTER CODE DEVELOPMENT (OCT 1998)

 Computer code
development (the writing of a new computer program or the enhancement of an existing program to expand its capabilities) even if not explicitly specified in the Tasks of the SOW, shall be accompanied by a report which will be a brief summary
describing the software, associated machine requirements and development and documentation status of each Computer Code for DTRA to determine the applicability of the Computer program to specific research programs. 

 

			
	 252.235-9000
	  	SOURCES OF INFORMATION (JULY 2000)

 a. The results of the
research to be delivered to the Government under this Contract shall embody the most recent reliable information in the field which is available to the Contractor from private and governmental sources, and the Contractor agrees to utilize all
sources of such information available to it. In this connection, information in this field which is in the control of DTRA shall, with the consent of the Contracting Officer’s Representative (COR) and under such safeguards and procedures as
he/she may prescribe, be made available to the Contractor on request. Additionally, the Contractor is encouraged to make use of the resources available through the Defense Threat Reduction Information Analysis Center (DTRIAC), 1680 Texas Street,
Southeast, Kirtland AFB, New Mexico 87117. 
 b. Reasonable assistance in obtaining access to information, or in obtaining permission to use
Government or private facilities, will be given to the Contractor by DTRA. Specifically, the Contractor must register with the Defense Technical Information Center, ATTN: DTIC, 8725 John J. Kingman Road, Suite 0944, Fort Belvoir, VA 22060-6218, in
accordance with Defense Logistics Agency (DLA) Regulation 4185.10, Certification and Registration for Access to DoD Defense Technical Information. DD Form 1540, the registration form, shall be forwarded to the DTRA Contracting Officer for approval
(DFARS 35.010(b)). 
 (End of clause) 
  

			
	 252.235-9001
	  	PROHIBITION OF USE OF LABORATORY ANIMALS (OCT 2008)(DTRA)

 No
animal studies may be conducted using DOD funds until Animal Care and Use Review Office (ACURO) approval has been granted. Studies involving non human primates, dogs, cats, or marine mammals will require a









 HDTRA1-10-C-004 

 Page
 33
 of 35 
  

 
site visit by a DoD laboratory animal veterinarian. The recipient (including subcontractors) is expressly forbidden to use laboratory animals in any manner whatsoever without the express written
approval of the US Army Medical Research and Material Command (MRMC), Animal Care and Use Review Office (ACURO). You must complete the ACURO Animal Use Appendix for Research Involving Animals found at the following web site:
https://mrmcwww.army.mil/AnimalAppendix.asp. Please submit the completed ACURO appendix, contact information, the DTRA contract number and a copy of the contract for processing to the email address listed at the ACURO website for processing. You
will receive written approval to begin research under the applicable protocol proposed for this award from the US Army MRMC ACURO under separate email to the recipient and Principal Investigator. A copy of this approval will be provided to the
Defense Threat Reduction Agency (DTRA) for the official file. Noncompliance with any provision of this clause may result in the termination of the award. 
  

			
	 252.242-9000
	  	CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (CPARS) (NOV 2002)


1. As required by FAR Parts 42 and 15, and DTRA policy for the Contractor Performance Assessment Reporting System (CPARS) and Past Performance Information
Retrieval System (PPIRS), formerly known as PPAIS, effective July, 2001, the Government shall complete a CPAR each year of the period of performance of this contract. The contractor will have an opportunity to provide their comments in each CPAR
before it is completed. In accordance with DTRA CPARS policy the completed CPARs will be entered into PPIRS, a retrieval system for Government source selection teams to access the CPARs of contractor’s performance. The DTRA CPARS and PPIRS
policy includes an explanation of the process and procedures that will be utilized under this contract. A copy is available for contractor reference via the DTRAlink (www.dtra.mil) by accessing Acquisition, Doing Business With Us. 

2. The CPARs shall occur annually in accordance with the schedule established below: 

(i) Initial CPAR: 12 months after contract start date (date performance begins) TBD (by PCO) 

(ii) Interim CPAR(s) will be performed annually on the anniversary of the contract start date according to the following schedule: TBD (by PCO)

 (iii) A Final CPAR will be completed upon contract termination, transfer of program management/contract management responsibility outside of
DTRA, the delivery of the final end item on contract and/or the completion of the performance period. 
 (iv) An Out-of-Cycle CPAR may be
required when there is a significant change in performance that alters the assessment in one or more evaluation area(s). An Out-of-Cycle CPAR is optional and shall be processed in accordance with DTRA CPARS policy referenced in paragraph 1. above.

 3. Each CPAR shall only cover the period elapsing from the last annual CPAR. The final CPAR shall not be used to summarize or
“roll-up” the contractor’s performance under the entire contract. Each annual CPAR and the final CPAR together will comprise a total picture of contractor performance. 

4. At the request of the Government, a verbal, informal review of the Contractor’s performance may be held 3-6 months before the completion of the
Interim or Final Evaluation periods. This review entails discussing any problems or areas of concern regarding the Contractor’s performance to date. No written evaluation form or other formal documentation is required for this evaluation. It
may be conducted with the Contractor by telephone, teleconference or face-to-face. This is designed to offer the Contractor an opportunity to correct known deficiencies or weaknesses prior to the formal written evaluation. 








 HDTRA1-10-C-004 

 Page
 34
 of 35 
  

 5. As set forth in DTRA CPARS policy, any disagreements between the Contractor and the Program Manager
regarding the CPAR(s) that cannot be resolved shall be reviewed by the designated Reviewing Official prior to completion of the CPAR. 
 6.
Special Requirements for Indefinite Delivery Contracts (IDIQ and Requirements type), CPARs shall be processed (select one)  

             for all existing orders (combined) at the time the CPAR is processed

              on an order-by-order basis 

             on a grouped order basis 

7. The policy and procedures set forth in this clause and DTRA CPARS policy are not subject to “Disputes” as described in FAR Part 33.

  

			
	 252.245-9000
	  	Government Property (AUG 2009)

 (a) In accordance with
FAR 52.245-1(b), Property Management, and FAR 52.245-1(f), Contractor Plans and Systems, the Contractor shall have a system to manage (control, use, preserve, protect, repair and maintain) Government property in its possession. 

(b) The Contract Data Requirements Lists (CDRLs) associated with the Property for this Contract are contained in Exhibit “A” and included in
Section J of this contract. The spreadsheet required by the CDRL entitled “Master Government Property List (MGPL) will be incorporated in Section J of this contract. 

(c) The Contractor shall provide to the Government an updated MGPL according to the CDRL. 

(d) The Government Site Visits/Physical Inventory – The DTRA will annually verify the Property in the Possession of the Contractor. The
Contactor’s Point of Contact shall coordinate with the Program Manager/Contracting Officer Representative or DTRA Accountable Property Officer (APO) on prearranged site visits upon request. 

(e) The Contractor shall annually conduct and provide to the DTRA a physical inventory report of ALL Government Property in its possession according to
the Master Government Property List (Physical Inventory) CDRL. 
 (f) The physical inventory report shall be validated/confirmed via signature
by both the Contractor’s Property Administrator and the DTRA’s Government Representative (i.e. COR, APO, etc.). Inventory discrepancies must be reported immediately to the Contracting Officer, COR/Program Manager and resolved by the DTRA
APO. 
 (g) The Contractor shall provide all CDRL reports to the Government electronically in a spreadsheet using Microsoft Office Excel. Unless
otherwise specified, the contractor shall submit all data through the IUID Registry. 
 (End of Clause) 

Exhibit/Attachment Table of Contents 








 HDTRA1-10-C-004 

 Page
 35
 of 35 
  


							
	DOCUMENT TYPE	 	DESCRIPTION	 	PAGES	 	DATE
	Exhibit A	 	CDRLS	 		 	09-DEC-2009
	Attachment 1	 	Statement of Work	 		 	30-NOV-2009








 EXHIBIT A 








																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA

 
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	  

D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	  

E. CONTRACT/PR NO.
	  	F. CONTRACTOR  

                    Trius Therapeutics,
Inc.
  
	  		  	
	 1.
DATA ITEM NO.
  
 A001
	 	 2. TITLE OF DATA ITEM

 
 Work Breakdown Structure

 
	  	 3. SUBTITLE

 
 3-Level Work Breakdown Structure

 
	  	 	  	 17. PRICE GROUP

 
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-MGMT-81334C

 
	  	5. CONTRACT REFERENCE  

NA
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ  
  

LT
	  	 9. DIST

 
 STATEMENT

REQUIRED    
  

NA
	  	 10. FREQUENCY

 
         See Blk 16

 
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16

 
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
 A
	  	  	 11. AS OF DATE

 
         See Blk 16

 
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
         See Blk
16
  
	  	  	DDraft  	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro  	  		  	
	
16. REMARKS
  

Three-Level WBS with costs & schedule per each level (top level is program, level 2 is base/options, level 3 are major tasks). For lowest task level
show breakdown for labor, material and other indirect costs. Blk 10-13: First report due 15 days prior to Kick-off as part of Project Management Plan (CDRL A011) submission. To be updated annually. Government may provide acceptable format.
Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A002

 
	 	 2. TITLE OF DATA ITEM

  
 Monthly Invoice Report

 
	  	 3. SUBTITLE

 
 NA

 
	  	 	  	 17. PRICE GROUP

  
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-FNCL-80331A

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
  
	  	 	  	18. ESTIMATED         TOTAL PRICE
	 7. DD
250 REQ
  
 LT

 
	  	 9. DIST

 
 STATEMENT

REQUIRED    
  

NA
  
	  	 10. FREQUENCY

 
 Monthly
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16

 
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A

 
	  	  	 11. AS OF DATE

 
 See Blk 16

 
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
 See Blk 16

 
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro	  		  
	
16. REMARKS
  

Summary of invoices submitted during previous month or last month for which unreported data is available. Blk 11-13: Report after first business day of
the month after contract initiation and every month thereafter.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED
BY
  
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA

 
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	  

D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
  
	  	  

E. CONTRACT/PR NO.
	  	F. CONTRACTOR  

                    Trius Therapeutics,
Inc.
	  		  	
	 1.
DATA ITEM NO.
  
 A003

 
	 	 2. TITLE OF DATA ITEM

 
 Quarterly Status Report

 
	  	 3. SUBTITLE

 
 Quarterly Contract Performance Re

 
	  	 	  	 17. PRICE GROUP

 
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-MGMT-80368A

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
  
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ  
  

LT
  
	  	 9. DIST

 
 STATEMENT

REQUIRED    
  

NA
  
	  	 10. FREQUENCY

 
         Quarterly
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16

 
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A

 
	  	  	 11. AS OF DATE

 
         See Blk 16

 
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
         See Blk
16
  
	  	  	DDraft  	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro  	  		  	
	
16. REMARKS
  

First report due within 15 days after the end of the first Fiscal Quarter (FQ) after award. Subsequent reports due within 15 days of the end of each FQ.
Report will address cost, schedule, performance (including pertinent technical data), and risk, to include updates to project expenditures. The 4th quarterly report for each
FY will include an Executive Summary for the entire FY. Government may provide acceptable format. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document
within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	 	  		 		  		  		  		  		  		  		  		  		  	 	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A004

 
	 	 2. TITLE OF DATA ITEM

  
 Integrated Master Schedule

 
	  	 3. SUBTITLE

 
 NA

 
	  	 	  	 17. PRICE GROUP

  
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-MGMT-81650

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
  
	  	 	  	18. ESTIMATED         TOTAL PRICE
	 7. DD
250 REQ
  
 LT

 
	  	 9. DIST

 
 STATEMENT

REQUIRED    
  

NA
  
	  	 10. FREQUENCY

 
 See Blk 16

 
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16

 
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A

 
	  	  	 11. AS OF DATE

 
 See Blk 16

 
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
 See Blk 16

 
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro	  		  
	
16. REMARKS
  

First report due 15 days prior to Kick-off. Microsoft Project compatible file required. Subsequent updates due within 15 days of each FQ end. Government
may provide acceptable format. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is
received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	 	  		 		  		  		  		  		  		  		  		  		  	 	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED
BY
  
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA

 
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	  

D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	  

E. CONTRACT/PR NO.
	  	F. CONTRACTOR  

                    Trius Therapeutics,
Inc.
	  		  	
	 1.
DATA ITEM NO.
  
 A005
	 	 2. TITLE OF DATA ITEM

 
 Final Report

 
	  	 3. SUBTITLE

 
 Final Project Report

 
	  	 	  	 17. PRICE GROUP

 
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-ADMN-80447A

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
  
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ  
  

LT
	  	 9. DIST

 
 STATEMENT

REQUIRED    
  

NA
  
	  	 10. FREQUENCY

 
         1 Time

 
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16

 
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A

 
	  	  	 11. AS OF DATE

 
         Project Completion

 
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
         See Blk
16
  
	  	  	DDraft  	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro  	  		  	
	
16. REMARKS
  

Submission within 30 days of completion of final task on contract. Contractor format acceptable. Final report must include final summary of cost/financial
data and project schedule in addition to performance. Government may provide acceptable format. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document
within 5 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	 	  		 		  		  		  		  		  		  		  		  		  	 	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A006

 
	 	 2. TITLE OF DATA ITEM

  
 Miscellaneous Data Submissions

 
	  	 3. SUBTITLE

 
 Point papers, briefings, technical presentations and publications

  
	  	 	  	 17. PRICE GROUP

  
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 NA

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
  
	  	 	  	18. ESTIMATED         TOTAL PRICE
	 7. DD
250 REQ
  
 LT
	  	 9. DIST

 
 STATEMENT

REQUIRED    
  

NA
  
	  	 10. FREQUENCY

 
 As required

 
	  	 12. DATE OF FIRST SUBMISSION

 
 As required

 
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A

 
	  	  	 11. AS OF DATE

 
 As required

 
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
 As required

 
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro	  		  
	
16. REMARKS
  

Submission frequency will average approximately twice per year and dates will be coordinated. Deliverables shall be compatible electronic media. Required
submissions include Point Papers, Briefings, TPP, PDP, ACURO Approvals, HROB Approvals. Unless government format is provided, contractor format is acceptable. Government review/approval is 15 days after receipt of first submittal. Provide changes to
draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	0	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	 	  		 		  		  		  		  		  		  		  		  		  	 	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED
BY
  
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	
D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	E. CONTRACT/PR NO.	  	 F. CONTRACTOR

 
             Trius
Therapeutics, Inc.
	  		  	
	 1.
DATA ITEM NO.
  
 A007
	  	 2. TITLE OF DATA ITEM

 
 Patent – Reporting of Subject Inventions
	  	 3. SUBTITLE

 
 NA
	  		  	
17. PRICE GROUP
  

 

	 4.
AUTHORITY (Data Acquisition Document No.)
  

NA
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

 
 STATEMENT  

REQUIRED      
  

NA
	  	 10. FREQUENCY

 
         Annually
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
         See Blk 16
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Provide report(s) every 12 months from the date of the contracts as identified in the DFARS 252.227-7039 (Patents – Reporting Subject Inventions (DD
Form 882 attached) and FAR 52.227-11.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A008
	  	 2. TITLE OF DATA ITEM

  
 Regulatory Approvals and Technical
Data Packages
	  	 3. SUBTITLE

 
 Submission Report (Regulatory Appr. Docs)
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

NA
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	18. ESTIMATED         TOTAL PRICE
	 7.
DD 250 REQ
  
 LT
	  	 9. DIST

 
 STATEMENT  

REQUIRED      
  

NA
	  	 10. FREQUENCY

 
 See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 See Blk 16
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Contractor will submit pre-IND, and/or pre-EUA to the FDA. Contractor will provide
the Government copies of all technical data generated by the contractor prior to and during performance of contract necessary to pursue FDA approval of pre-IND, IND, or pre-EUA, and notify the Government of FDA decisions. All written communications
to and/or from the FDA will he provided to the Government. Government review is 15 days after receipt of first submittal and will not impede submission of documents to FDA by Contractor.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED BY

 
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	
D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	E. CONTRACT/PR NO.	  	 F. CONTRACTOR

 
             Trius
Therapeutics, Inc.
	  		  	
	 1.
DATA ITEM NO.
  
 A009
	  	 2. TITLE OF DATA ITEM

 
 In-Process Review
	  	 3. SUBTITLE

 
 NA
	  		  	
17. PRICE GROUP
  

 

	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-80368A
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

 
 STATEMENT  

REQUIRED      
  

NA
	  	 10. FREQUENCY

 
         Bianually
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
         See Blk 16
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Contractor present project status formally to the Government no more than every 6 months in accordance with a Government provided agenda. The information
contained in the In Process Review (IPR) is similar to that contained in the Quarterly Status Report (QSR, CDRL A003) but in a presentation format. Unless government format is provided, contractor format is acceptable. Government review/approval is
15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A010
	  	 2. TITLE OF DATA ITEM

  
 Expenditure Forecast
	  	 3. SUBTITLE

 
 Project Spend Plan
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-81468
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	18. ESTIMATED         TOTAL PRICE
	 7.
DD 250 REQ
  
 LT
	  	 9. DIST

 
 STATEMENT  

REQUIRED      
  

NA
	  	 10. FREQUENCY

 
 See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 See Blk 16
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Contractor will provide an updated expenditure forecast reflecting actual negotiated
costs over the lifetime of the project 15 days prior to Kick-off, and will update the forecast as requested by the Government. Unless government format is provided, contractor format is acceptable. Government review/approval is 15 days after receipt
of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED BY

 
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	
D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	E. CONTRACT/PR NO.	  	 F. CONTRACTOR

 
             Trius
Therapeutics, Inc.
	  		  	
	 1.
DATA ITEM NO.
  
 A0011
	  	 2. TITLE OF DATA ITEM

 
 Project Management Plan
	  	 3. SUBTITLE

 
 NA
	  		  	
17. PRICE GROUP
  

 

	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-80004A
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

 
 STATEMENT  

REQUIRED      
  

NA
	  	 10. FREQUENCY

 
         See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	 14. DISTRIBUTION
  
	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
         See Blk 16
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Includes organizational chart, initial WBS, initial Integrated Master Plan, Risk Management Plan, and Regulatory Affairs Plan. Due 15 days prior to
Kick-off. Government may provide acceptable format. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days of such request. Provide final
document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
	  	 2. TITLE OF DATA ITEM

  
	  	 3. SUBTITLE

 
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  
	  	 5. CONTRACT REFERENCE

 
	  	 6. REQUIRING OFFICE

 
	  		  	 18. ESTIMATED
        TOTAL PRICE
  

	 7.
DD 250 REQ
  
	  	 9. DIST

 
 STATEMENT  

REQUIRED      

 
	  	 10. FREQUENCY

 
	  	 12. DATE OF FIRST SUBMISSION

 
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
	  	  	 11. AS OF DATE

 
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	16. REMARKS	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	 	  	 	  	 	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED BY

 
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	
D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	E. CONTRACT/PR NO.	  	 F. CONTRACTOR

 
 Trius Therapeutics, Inc.

 
	  		  	
	 1.
DATA ITEM NO.
  
 A012
	  	 2. TITLE OF DATA ITEM

 
 Master Government Property List
	  	 3. SUBTITLE

 
 GFP, GFE, GFM and Contractor Acquired Property
	  		  	
17. PRICE GROUP
  

 

	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-80269
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/BE-BL_
	  		  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

 
 STATEMENT  

REQUIRED      
  

NA
	  	 10. FREQUENCY

 
 Monthly
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

A
	  	  	 11. AS OF DATE

 
 Award
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 See Blk 16
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Block 4: This DID is for reference only. The report shall be prepared according to
the remarks below.
 Block 12: 45th calendar day following contract
award.
 Block 13: Tenth calendar day of each month.
  

During performance of the Contract, the Contractor may purchase material or equipment using Government funds [Contractor Acquired Property (CAP)] if it is
approved by the Contracting Officer. The Contractor shall provide a Master Government Property List (MGPL) inclusive of all CAP on the 45th calendar day following Contract
award and the tenth calendar day of each subsequent month.
  
 The MGPL shall
include all equipment/property provided to the contract, including equipment transferred between projects, broken and obsolete equipment, and items purchased outside the United States. The MGPL shall consist of the following data elements at a
minimum: Accountable Contract, Property Name, Original Manufacturer’s Name, Description/Commercial Use, Original Manufacturer’s Part Number, Model Number, Serial Number, DTRA Asset ID Number, Equipment Identification Number Quantity,
Contract to which equipment is assigned, Work Breakdown Structure Project Number, Item Unique Identifier or equivalent, Project Descriptor, Equipment Location, Date Placed In Service, Condition of Property (active, stored, in-transit or waiting
disposal), Government Property Type (Government Furnished Equipment, Government Furnished Material, Government Furnished Property, CAP), Unit Acquisition Cost (from accounting system) and Remarks.

 
 The MGPL shall be delivered electronically in a spreadsheet using Microsoft Office
Excel. Abbreviations are not allowed.
  
 Ninety (90) days prior to Contract
expiration, the Contractor shall submit a final MGPL suitable for close-out purposes containing use/disposition recommendations.
  
	  	DTRA/BE-BL_	  	 	  	 	  	1	  		  	
	  	DTRA/BE-BF_	  	 	  	 	  	1	  		  	
	  	DTRA/BE-BC_	  	 	  	 	  	1	  		  	
	  	DTRA/TMTI	  	 	  	 	  	1	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 15. TOTAL

 
  
	  	 	  	 	  	4  

 
	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED BY

 
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	









																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 110 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to Department of Defense, Washington Headquarters Services, Directorate for information Operations and Reports (0701-0188), 1215
Jefferson Davis Highway, Suite 1204, Arlington, VA, 22202-4302. Respondents should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection or information if it does
no display a currently valid OMB control number. Please DO NOT RETURN your form to the above address. Send completed form to the Government Issuing Contracting Officer for the Contract/PR No. Listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM

NO.
 NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	
D. SYSTEM/ITEM
  

Transformational Medical Tech Initiative
	  	E. CONTRACT/PR NO.	  	 F. CONTRACTOR

 
 Trius Therapeutics, Inc.
	  		  	
	
1. DATA ITEM NO.
  

A013
	  	 2. TITLE OF DATA ITEM

 
 Master Government Property – Physical Inventory
	  	 3. SUBTITLE

 
 GFP, GFE, GFM and Contractor Acquired Property
	  		  	
17. PRICE GROUP
  

 

	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-80441
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/BE-BL_
	  		  	 18. ESTIMATED

TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

STATEMENT
 REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 Annually
	  	 12. DATE OF FIRST SUBMISSION

 
 One Month after award
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

A
	  	  	 11. AS OF DATE

 
 Award
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 Annually
	  	  	DDraft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Block 4: This DID is for reference only. The report shall be prepared according to
the remarks below.
  
 The Contractor shall annually perform, record and
disclose physical inventory results of all Government Property/Contractor Acquired Property (CAP)/Equipment/Material. A final coordinated physical inventory shall be performed upon contract completion or termination and approved by the DTRA
Accountable Property Officer.
  
 The Physical Inventory Report shall
indentify the Contractor’s Point of Contact with telephone number and signature and shall consist of the following data elements at a minimum: Accountable Contract, Property Name, Original Manufacturer’s Name, Description/Commercial Use,
Original Manufacturer’s Part Number, Model Number, Serial Number, DTRA Asset ID Number, Equipment Identification Number Quantity, Contract to which equipment is assigned, Work Breakdown Structure Project Number, Item Unique Identifier or
equivalent, Project Descriptor, Equipment Location, Date Placed In Service, Condition of Property (active, stored, in-transit or waiting disposal), Government Property Type (Government Furnished Equipment, Government Furnished Material, Government
Furnished Property, CAP), Unit Acquisition Cost (from accounting system) and Remarks.
  

The Physical Inventory Report shall be documented in writing and validated/confirmed by both the Contractor’s Property Administrator and the DTRA PM.
Inventory discrepancies must be reported immediately to the Contracting Officer, PM or the DTRA Accountable Property Officer. The report shall contain original signatures and be delivered electronically in a spreadsheet using Microsoft Office Excel.
Abbreviations are not allowed.
  
 Ninety (90) days prior to Contract
expiration, the Contractor shall submit a final property identification listing suitable for close-out purposes containing use/disposition recommendations. The report must be reviewed, approved and signed by the DTRA Accountable Property Officer
prior to contract close out.
	  	DTRA/BE-BL_	  	 	  	 	  	1	  		  	
	  	DTRA/BE-BF_	  	 	  	 	  	1	  		  	
	  	DTRA/BE-BC_	  	 	  	 	  	1	  		  	
	  	DTRA/TMTI	  	 	  	 	  	1	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL	  	 	  	 	  	4	  		  	
	  	 	  	 	  	 	  		  		  	
	  	 	  	 	  	 	  		  		  	
	  	 	  	 	  	 	  	 	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 12-14-2009
	  	 I. APPROVED BY

 
 /s/ Unknown Signatory
	  	 J. DATE

 
 /s/ 12-17-2009
	  		  	








 SCHEDULE 1 








 



 
  

 Broad Spectrum Antibacterial Therapeutics from Marine Natural Products

 TMTI-DRUG-02: Trius Therapeutics 

Statement of Work 
 1.0–
Objective: The goal of this program is to develop a safe, potent antimicrobial agent derived from marine sediment actinomycete fermentations. The agent will have a novel, bacterial-specific mechanism of action for the prophylaxis and treatment
of infectious diseases caused by Category A and B bacterial pathogens. We will maximize the opportunity for rapid progress by collecting and fermenting novel actinomycetes from a novel resource, marine sediments. We will minimize the time for
discovery of novel mechanism antibacterials using our unique collection of Bacillus anthracis antisense strains hypersensitized to [...***...] different bacterial-specific essential targets. We will accelerate development of
therapeutics from these discoveries using our structural biology platform to co-crystallize the natural products with the protein targets, thus allowing semi-synthetic modification to optimize the drug properties. [...***...]. The resulting
therapeutics will show no cross-resistance to existing drugs and a broad pathogen spectrum. Thus, we mitigate the defense threat and aid the warfighter by providing a unique, cost-effective solution to counter multiple possible bacterial biowarfare
agents with a single therapeutic agent. 
 2.0 – Scope: This proposal to develop therapeutic countermeasures against Category A and
B bacterial pathogens is in support of the Defense Threat Reduction Agency (DTRA) Chemical and Biological Defense Medical S&T Division research and development program. The scope of work for this contract falls into the following 4 stages:
[...***...] Time frames are shown below with more details of the Base period, Option Periods and Option Tasks outlined in Attachment 1. 

In Option Task 1, [...***...]. 

It is anticipated that [...***...]. However, the other studies [...***...] compound. DTRA has [...***...] and
[...***...], to be triggered at the discretion of DTRA (see figure below). 
  


					
	V03.31.10	 	1	 	***Confidential Treatment Requested











 

 

  

 Period of Contract and Budget 

[...***...] 
 3.0 – Background:

 Bioweapons derived from bacterial pathogens are a serious and present danger to the warfighter. The nature of these bacterial bioweapons
will require therapeutics with novel mechanisms of action because of the likelihood that such bioweapons will be engineered for resistance against 

 


					
	V03.31.10	 	2	 	***Confidential Treatment Requested











 

 

  

 
known therapeutics. New antibacterial therapeutics to address this danger are not currently in development. The reality of the danger combined with the paucity of new therapeutics creates a
strong urgency for a rapid process with a high likelihood of success. Bacteria of the subgroup Actinomycetales have been the most prolific source of new antibiotics, providing more than 80% of the antibiotic drugs in use today. The method of
discovering antibacterials from soil-derived actinomycetes is well established and includes fermenting the bacteria to elicit production of secondary metabolites, extraction of the resulting broth and then testing for antibacterial activity. Because
of the long effort by countless numbers of researchers examining terrestrial soil, it is increasingly difficult to find novel antibacterials from this source with properties useful in addressing the biowarfare pathogens contemplated here.

 While the search for antimicrobials from the soil-based milieu has reached a point of diminishing returns, recent
advances in marine microbiology have opened unprecedented opportunities for the discovery of useful new antibiotics from ocean sediment microorganisms. [...***...] 

The Base period milestone is [...***...]. The goal of Option Period 1 is [...***...] into Option 2
(preclinical), where the milestone is [...***...]. Up to [...***...] studies. [...***...]. 
 4.0-
Tasks/ Technical Requirements: 
 BASE PERIOD 1 (18 months): [...***...] 

4.0 The contractor should [...***...]. 

The contractor shall [...***...]. 
  


					
	V03.31.10	 	3	 	***Confidential Treatment Requested











 

 

  

 Option Task 4.1: [...***...]. 

4.1 The contractor shall [...***...]. 

4.2 The contractor shall [...***...]. 

4.3 The contractor shall [...***...]. 

[...***...] 

GOAL: [...***...]. 

BASE PERIOD INTERIM MILESTONE ([...***...]): The contractor should [...***...]. 

BASE PERIOD INTERIM MILESTONE ([...***...]): The contractor should [...***...]. 

4.4 The contractor should [...***...]. 

4.4.1 The contractor should [...***...] 

4.4.2 The contractor should [...***...] 

4.4.3 The contractor should [...***...] 

4.4.4 The contractor should [...***...] 

4.5 The contractor should characterize the activity of the isolated components 

[...***...] 
  


					
	V03.31.10	 	4	 	***Confidential Treatment Requested











 

 

  

 [...***...] 

4.6. The contractor should [...***...] 

BASE PERIOD MILESTONE [...***...]. 

[...***...]. 

[...***...]. 
 OPTION PERIOD
1 [...***...] 
 4.7. The contractor [...***...] 

4.8. The contractor should [...***...] 
  


					
	V03.31.10	 	5	 	***Confidential Treatment Requested











 

 

  

 4.9. The contractor should [...***...] 

4.9.1 The contractor should [...***...] 

4.9.2 The contractor should [...***...] 

OPTION 1 INTERIM MILESTONE: The contractor should [...***...]. 

OPTION 1 INTERIM MILESTONE: The contractor should [...***...]. 

OPTION 1 MILESTONE: The contractor should [...***...]. 

OPTION 1 MILESTONE: The contractor should [...***...] 

OPTION PERIOD 2 [...***...] 

4.10. The contractor shall [...***...] 
  


					
	V03.31.10	 	6	 	***Confidential Treatment Requested











 

 

  

 [...***...] 

OPTION PERIOD 2 MILESTONE: The contractor should [...***...] 

] 
 OPTION PERIOD
[...***...] 
 4.12. The contractor shall [...***...] 

4.13. The contractor should [...***...] 

4.14. The contractor shall [...***...] 

4.15. The contractor shall [...***...] 

4.16 The contractor should [...***...] 

OPTION PERIOD 3 MILESTONE: [...***...] 
  


					
	V03.31.10	 	7	 	***Confidential Treatment Requested











 

 

  

 The contractor [...***...] 

OPTION PERIOD 3 [...***...] 

ALL BASE AND OPTION PERIODS 

FY1-FY5 
 Management 

4.19. The contractor shall 

[...***...] 
 4.20.
[...***...] 
 4.21: The contractor shall [...***...] 

5.0- CDRLs/Other deliverables: 
  

	1.	The contractor shall [...***...] 

  

	2.	The contractor shall [...***...] 

  


					
	V03.31.10	 	8	 	***Confidential Treatment Requested











 

 

  


	3.	The contractor shall [...***...] 

  

	4.	The contractor shall [...***...] 

  

	 	a.	The contractor shall [...***...] 

  

	 	b.	The contractor shall [...***...] 

  

	5.	The contractor shall [...***...] 

  

	6.	The contractor shall [...***...] 

  

	7.	The contractor shall [...***...] 

  

	8.	The contractor shall [...***...] 

  

	9.	The contractor shall [...***...] 

  

	10.	The contractor shall [...***...] 


Attachment 1: SUMMARY OF TASKS/TECHNICAL REQUIREMENTS 
  



					
	V03.31.10	 	9	 	***Confidential Treatment Requested











 

 

  

 [...***...] 

 


					
	V03.31.10	 	10	 	***Confidential Treatment Requested











 

 

  

 [...***...] 

 


					
	V03.31.10	 	11	 	***Confidential Treatment Requested









 Attachment 2: CONTRACT DATA REQUIREMENT LIST 

 

																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data Items)
	  	 Form Approved

OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents should be aware that notwithstanding any
other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send
completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM
 NO.

 NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:
  

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	E. CONTRACTOR/PR NO.	  	 F. CONTRACTOR

 
 Trius Therapeutics
	  		  	
	 1.
DATA ITEM NO.
  
 A001
	  	 2. TITLE OF DATA ITEM

 
 Work Breakdown Structure
	  	 3. SUBTITLE

 
 3-Level Work Breakdown Structure
	  		  	
17. PRICE GROUP
  

 

	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-81334C
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	 18. ESTIMATED

TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
         See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
         See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

3-Level WBS with costs & schedule per each level. For lowest task level show breakdown for labor, material and other indirect costs. Blk 10-13: First
report due 15 days past award. Formal provided to contractor. To be updated annually. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10
days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTALg	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A002
	  	 2. TITLE OF DATA ITEM

  
 Monthly Invoice Report
	  	 3. SUBTITLE

 
 NA
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-FNCL-80331A
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	18. ESTIMATED TOTAL PRICE
	 7.
DD 250 REQ
  
 LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 Monthly
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Summary of invoices submitted during previous month or last month for which
unreported data is available Format provided to contractor. Blk 11-13 Report after first business day of the month after contract award and every month thereafter.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTALg	  	0	  	2	  	0	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED BY
	  	 J. DATE

 
	  		  	


																	
	  DD FORM 1423-2, AUG 96	  	PREVIOUS EDITION MAY BE USED.	  		  	 Page      of      Pages

Adobe Professional 7.0
	  	

  


					
	V03.31.10	 	12	 	










																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data Items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents should be aware that notwithstanding any
other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send
completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM NO.

NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:
  

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	E. CONTRACTOR/PR NO.	  	 F. CONTRACTOR

 
 Trius Therapeutics

 
	  		  	
	 1.
DATA ITEM NO.
  
 A003
	  	 2. TITLE OF DATA ITEM

 
 Quarterly Status Report
	  	 3. SUBTITLE

 
 Quarterly Contract Performance Report

 
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-ADMN-80447
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	 18. ESTIMATED

TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
         Quarterly
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
         See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Blks 11-13: First report due within 15 days after the end of the first Fiscal Quarter post award. Subsequent reports due within 15 days of the end of each
FQ. Format provided to the contractor. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is
received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTALg	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A004
	  	 2. TITLE OF DATA ITEM

  
 Quarterly Financial Status Report
	  	 3. SUBTITLE

 
 NA
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-FNCL-80331A
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	18. ESTIMATED TOTAL PRICE
	 7.
DD 250 REQ
  
 LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 Quarterly
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Blks 11-13: First report due within 15 days after the end of the first Fiscal Quarter
post award. Subsequent reports due within 15 days of the end of each FQ. Format provided to the contractor. Report should include expenditures to each item in the 3-Level WBS. Government review/approval is 15 days after receipt of first submittal.
Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTALg	  	0	  	2	  	0	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED BY

 
	  	 J. DATE

 
	  		  	


																	
	  DD FORM 1423-2, AUG 96	  	PREVIOUS EDITION MAY BE USED.	  		  	Page      of      Pages	  	

  


					
	V03.31.10	 	13	 	









 Adobe Professional
7.0                                         
     

																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data Items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	The public reporting burden for this collection of information is estimated to
average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding this
burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents should be aware that notwithstanding any
other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your form to the above organization. Send
completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.	  		  	
	
A.  CONTRACT LINE ITEM NO.

NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:
  

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	E. CONTRACTOR/PR NO.	  	 F. CONTRACTOR

 
 Trius Therapeutics, Inc.

 
	  		  	
	 1.
DATA ITEM NO.
  
 A005
	  	 2. TITLE OF DATA ITEM

 
 Annual Report
	  	 3. SUBTITLE

 
 Cumulative Annual Progress Report

 
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-ADMN-80447
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	 18. ESTIMATED

TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
         See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
         See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Blks 10-13: First submission within 15 days after the end of the first Fiscal Year following award. Subsequent reports due within 15 days after the end of
the Fiscal Year. Format as provided to contractor. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is
received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTALg	  	0	  	2	  	0	  		  	
	 1. DATA ITEM NO.

 
 A006
	  	 2. TITLE OF DATA ITEM

  
 Integrated Master Schedule
	  	 3. SUBTITLE

 
 NA
	  		  	17. PRICE GROUP
	 4.
AUTHORITY (Data Acquisition Document No.)
  

DI-MGMT-81650
	  	 5. CONTRACT REFERENCE

 
 NA
	  	 6. REQUIRING OFFICE

 
 DTRA/TMTI
	  		  	18. ESTIMATED TOTAL PRICE
	 7.
DD 250 REQ
  
 LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  		  	 
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP CODE

 
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT SUBMISSION

 
 See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	 16. REMARKS

 
 Blk 10-13: First report due 15 days past award. Format provided to contractor.
Subsequent reports due within 15 days of FQ end. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is
received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTALg	  	0	  	2	  	0	  		  	
	 G.
PREPARED BY
  
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED BY

 
	  	 J. DATE

 
	  		  	


																	
	  DD FORM 1423-2, AUG 96	  	PREVIOUS EDITION MAY BE USED.	  		  	 Page      of      Pages

Adobe Professional 7.0
	  	

  


					
	V03.31.10	 	14	 	










																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data Items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	 The public reporting burden for
this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of
information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents
should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your
form to the above organization. Send completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
	  		  	
	
A.  CONTRACT LINE ITEM NO.
  

NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	E. CONTRACTOR/PR NO.	  	F. CONTRACTOR  

                    Trius
Therapeutics
	  		  	
	 1.
DATA ITEM NO.
  
 A007
	 	 2. TITLE OF DATA ITEM

 
 Final Report

 
	  	 3. SUBTITLE

 
 Final Project Report

 
	  	 	  	 17. PRICE GROUP

 
  

	
4. AUTHORITY (Data Acquisition Document No.)

 
 DI-ADMN-084478

 
	  	5. CONTRACT REFERENCE  

NA
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

STATEMENT
 REQUIRED

 
 NA
	  	 10. FREQUENCY

 
         1 Time
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP
CODE
 A
	  	  	 11. AS OF DATE

 
         Project End
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  

        NA
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  	
	
16. REMARKS
  

Blk 12: Submission within 15 days of completion of final task. Contractor format acceptable. Final report must include final summary of cost/financial
data and project schedule in addition to performance. Government review/approval is 15 days after receipt of first submittal. Provide final document within 10 days of such request. Provide final document within 10 days after approval of changes is
received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	  	 	  	 	  	 	  		  		  	
	 1. DATA ITEM NO.

 
 A008
	 	 2. TITLE OF DATA ITEM

  
 Miscellaneous Data Submission

 
	  	 3. SUBTITLE

 
 Point Papers, Briefings, TPP, PDP,

Technical Presentations and Publications
  
	  	 	  	 17. PRICE GROUP

  
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 NA

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	18. ESTIMATED         TOTAL PRICE
	 7. DD
250 REQ
  
 LT
	  	 9. DIST

STATEMENT
 REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 As Required
	  	 12. DATE OF FIRST SUBMISSION

 
 As Required
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A
	  	  	 11. AS OF DATE

 
 As Required
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
 As Required
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Submission frequencies and dates will be coordinated. Deliverables shall be compatible electronic media. Unless format is provided, contractor format is
acceptable. Required submissions include Point Papers, Briefings, TPP, PDP, ACURO Approvals, HROB Approvals, Technical Presentations and Publications. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft
within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED
BY
  
	  	 J. DATE

 
	  		  	
	    DD FORM 1423-2, AUG 96
	  	PREVIOUS EDITION MAY BE USED.	  		  	
Page      of      Pages

Adobe Professional 7.0
	  		  	

  


					
	V03.31.10	 	15	 	










																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data Items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	 The public reporting burden for
this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of
information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents
should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your
form to the above organization. Send completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
	  		  	
	
A.  CONTRACT LINE ITEM NO.
  

NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	E. CONTRACTOR/PR NO.	  	F. CONTRACTOR  

                    Trius
Therapeutics
	  		  	
	 1.
DATA ITEM NO.
  
 A009
	 	 2. TITLE OF DATA ITEM

 
 Patents – Reporting of
Subject    
 Inventions
  
	  	 3. SUBTITLE

 
 NA

 
	  	 	  	 17. PRICE GROUP

 
  

	
4. AUTHORITY (Data Acquisition Document No.)

 
 DI-MISC-80711A

 
	  	5. CONTRACT REFERENCE  

NA
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ  
  

LT
	  	 9. DIST STATEMENT
REQUIRED    
  
 NA
	  	 10. FREQUENCY

 
         Annually
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
 A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
         See Blk
16
	  	  	Draft  	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro  	  		  	
	
16. REMARKS
  

Blk 11-13: Provide report(s) every 12 months from the date of the contract as identified in the DFARS 252.227-7039 (Patents – Reporting Subject
Inventions (DD Form 882 attached) and FAR 52.227-11.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	  	 	  	 	  	 	  		  		  	
	 1. DATA ITEM NO.

 
 A010
	 	 2. TITLE OF DATA ITEM

  
 Regulatory Approval and Technical Data
Packages
  
	  	 3. SUBTITLE

 
 Submission Report (Regulatory Appr. Docs)

 
	  	 	  	 17. PRICE GROUP

  
  

	
4. AUTHORITY (Data Acquisition Document No.)

 
 NA

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	18. ESTIMATED         TOTAL PRICE
	 7. DD
250 REQ
  
 LT
	  	 9. DIST STATEMENT
REQUIRED    
  
 NA
	  	 10. FREQUENCY

 
 See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
 See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro	  		  
	
16. REMARKS
  

Blk 10-13: Contractor will provide the Government copies of all technical data generated by the contractor prior to and during performance of contract
necessary to pursue FDA approval of IND, NDA, and notify the Government of FDA decisions. All written communications to and/or from the FDA will be provided to the Government. Government review/approval is 15 days after receipt of first submittal.
Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED
BY
  
	  	 J. DATE

 
	  		  	
	    DD FORM 1423-2, AUG 96
	  	PREVIOUS EDITION MAY BE USED.	  		  	
Page      of      Pages

Adobe Professional 7.0
	  		  	

  


					
	V03.31.10	 	16	 	










																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (2 Data Items)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	 The public reporting burden for
this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of
information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents
should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your
form to the above organization. Send completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
	  		  	
	
A.  CONTRACT LINE ITEM NO.
  

NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	E. CONTRACTOR/PR NO.	  	F. CONTRACTOR  

                    Trius
Therapeutics
	  		  	
	 1.
DATA ITEM NO.
  
 A011
	 	 2. TITLE OF DATA ITEM

 
 In Process Review

 
	  	 3. SUBTITLE

 
 NA

 
	  	 	  	 17. PRICE GROUP

 
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-MGMT-80227 &
DI-MGMT-80555A
  
	  	5. CONTRACT REFERENCE  

NA
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ
  

LT
	  	 9. DIST

STATEMENT
 REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 every 6 months
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP
CODE
 A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
         See Blk
16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  	
	
16. REMARKS
  

Blk 11-13: Contractor present project status formally to the Government every 6 months in accordance with a Government provided agenda. Government
review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such request. Provide final document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	  	 	  	 	  	 	  		  		  	
	 1. DATA ITEM NO.

 
 A012
	 	 2. TITLE OF DATA ITEM

  
 Expenditure Forecast

 
	  	 3. SUBTITLE

 
 Project Spend Plan

 
	  	 	  	 17. PRICE GROUP

  
  

	 4. AUTHORITY (Data Acquisition
Document No.)
  
 DI-MGMT-81468

 
	  	5. CONTRACT REFERENCE  

NA
  
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	18. ESTIMATED         TOTAL PRICE
	 7. DD
250 REQ
  
 LT
	  	 9. DIST

STATEMENT
 REQUIRED

 
 NA
	  	 10. FREQUENCY

 
 See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
 See Blk 16
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE	  	b. COPIES	  		  	 
	 8. APP
CODE
  
 A
	  	  	 11. AS OF DATE

 
 See Blk 16
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
 See Blk 16
	  	  	Draft	  	Final	  		  	
	  	  	  	  	  	  	Reg	  	Repro	  		  
	
16. REMARKS
  

Blks 10-13: Contractor will provide an updated expenditure forecast reflecting actual negotiated costs over the lifetime of the project 15 days past
award, and will update the forecast as requested by the Government. Format as provided to contractor. Government review/approval is 15 days after receipt of first submittal. Provide changes to draft within 10 days of such requesT. Provide final
document within 10 days after approval of changes is received.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED
BY
  
	  	 J. DATE

 
	  		  	
	    DD FORM 1423-2, AUG 96
	  	PREVIOUS EDITION MAY BE USED.	  		  	
Page      of      Pages

Adobe Professional 7.0
	  		  	

  


					
	V03.31.10	 	17	 	










																																			
	 CONTRACT DATA REQUIREMENTS LIST

 (1 Data Item)
	  	
            Form Approved

            OMB No. 0704-0188
	  		  	
	 The public reporting burden for
this collection of information is estimated to average 220 hours per response, including the time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of
information. Send comments regarding this burden estimate or any other aspect of this collection of information, including suggestions for reducing the burden, to the Department of Defense, Executive Services Directorate (0704-0188). Respondents
should be aware that notwithstanding any other provision of law, no person shall be subject to any penalty for failing to comply with a collection of information if it does not display a currently valid OMB control number. Please do not return your
form to the above organization. Send completed forms to the Government Issuing Contracting Officer for the Contract/PR No. listed in Block E.
	  		  	
	
A.  CONTRACT LINE ITEM NO.
  

NA
	  	 B. EXHIBIT

 
 A
	  	 C. CATEGORY:

 

TDP                      
TM                      OTHER                
      
	  	 	  		  	
	 D.
SYSTEM/ITEM
  
 Chemical/Biological Medical System
	  	 E. CONTRACTOR/PR NO.

 
 NA
	  	F. CONTRACTOR  

                    Trius
Therapeutics
	  		  	
	 1.
DATA ITEM NO.
  
 A013
	 	 2. TITLE OF DATA ITEM

 
 Project Management Plan

 
	  	 3. SUBTITLE

 
 NA

 
	  	 	  	 17. PRICE GROUP

 
  

	
4. AUTHORITY (Data Acquisition Document No.)

 
 DI-MGMT-80004A

 
	  	5. CONTRACT REFERENCE  

NA
	  	 6. REQUIRING OFFICE
  

DTRA/TMTI
	  	 	  	 18. ESTIMATED

        TOTAL PRICE

	
7. DD 250 REQ  
  

LT
	  	 9. DIST STATEMENT REQUIRED

 
 NA
	  	 10. FREQUENCY

 
         See Blk 16
	  	 12. DATE OF FIRST SUBMISSION

 
         See Blk 16
	  	14. DISTRIBUTION	  	 	  
	  	  	  	  	a. ADDRESSEE  	  	b. COPIES	  		  	 
	 8. APP
CODE
 A
	  	  	 11. AS OF DATE

 
         See Blk 16
	  	 13. DATE OF SUBSEQUENT
SUBMISSION
  
         See Blk
16
	  	  	Draft  	  	Final	  		  	
	  	  	  	  	  	  	Reg  	  	Repro  	  		  	
	
16. REMARKS
  

Includes organizational chart, initial WBS, initial Integrated Master Plan, Risk Management Plan, Regulatory Affairs Plan. Formats provided to contractor.
Due within 15 days past award.
	  	DTRA/TMTI	  	 	  	1	  	 	  		  	
	  	DTRA/BCR	  	 	  	1	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	 	  	 	  	 	  	 	  		  	
	  	15. TOTAL g	  	0	  	2	  	0	  		  	
	  	 	  	 	  	 	  		  		  	
	 G. PREPARED BY

 
 /s/ William Jones
	  	 H. DATE

 
 June 25, 2009
	  	 I. APPROVED
BY
  
	  	 J. DATE

 
	  		  	
	    DD FORM 1423-2, AUG 96
	  	PREVIOUS EDITION MAY BE USED.	  		  	
Page      of      Pages

Adobe Professional 7.0
	  		  	

  


					
	V03.31.10	 	18