exv10w33






Exhibit 10.33




EXECUTION VERSION




AMENDMENT AND RESTATEMENT AGREEMENT TO THE

CREDIT AGREEMENT



27 APRIL 2011



DRILLSHIP KITHIRA OWNERS INC.

as Owner



DEUTSCHE BANK AG, LONDON BRANCH

as Bookrunner and Mandated Lead Arranger



DEUTSCHE BANK AG, LONDON BRANCH

as Swap Bank



DEUTSCHE BANK LUXEMBOURG S.A.

as Facility Agent for itself and on behalf of various financial institutions as Lenders



and



DEUTSCHE BANK AG FILIALE DEUTSCHLANDGESCHÄFT

as Security Trustee



ALLEN & OVERY



Allen & Overy LLP



 









 





CONTENTS




	 	 	 	 	 
	Clause	 	Page	 
	1. Definition and Interpretation .
	 	 	1	 
	2. Amendment and Restatement
	 	 	2	 
	3. Finance Documents
	 	 	2	 
	4. Counterparts
	 	 	2	 
	5. Governing Law
	 	 	2	 
	6. Jurisdiction
	 	 	2	 
	7. Service of process
	 	 	3	 
	8. Waiver of immunity
	 	 	3	 
	 
	 	 	 	 
	Schedule
	 	 	 	 
	 
	 	 	 	 
	1. Original Lenders
	 	 	4	 
	2. Conditions Precedent
	 	 	5	 
	3. Form of Effective Date Notice
	 	 	7	 
	4. Amended and Restated Credit Agreement
	 	 	8	 
	 
	 	 	 	 
	Signatories
	 	 	9	 






 









 





THIS AMENTDMENT AND RESTATEMENT AGREEMENT is dated 27 April 2011




BETWEEN:





	(1)	 	DRILLSHIP KITHIRA OWNERS INC. a corporation incorporated in the Marshall Islands with
registered address at Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall
Islands MH 96960 as borrower (the Owner);
	 
	(2)	 	DEUTSCHE BANK AG, LONDON BRANCH as bookrunner and mandated lead arranger and bookrunner (in
this capacity the Bookrunner and Mandated Lead Arranger);
	 
	(3)	 	DEUTSCHE BANK AG, LONDON BRANCH as swap bank (in this capacity the Deutsche Swap Bank);
	 
	(4)	 	DEUTSCHE BANK LUXEMBOURG S.A. as facility agent for itself and on behalf of the financial
institutions listed in Schedule 1 (Original Lenders) as original lenders (the Original Lenders) (in
this capacity the Facility Agent); and
	 
	(5)	 	DEUTSCHE BANK AG FILIALE DEUTSCHLANDGESCHAFT as security trustee (in this capacity the Security
Trustee).





WHEREAS:





	(A)	 	Pursuant to a credit agreement dated 18 July 2008 as amended on 17 September 2008, 18 December
2008 and 29 January 2010 and now between, amongst others, the Owner as borrower, the Facility
Agent, the Mandated Lead Arranger and the Security Trustee (the Credit Agreement), the Owner agreed
to borrow and the Original Lenders, together with Dexia Credit Local, New York Branch (Dexia),
agreed to lend upon the terms and conditions mentioned in the Credit Agreement.
	 
	(B)	 	On or about the date of this Agreement, Dexia was prepaid all outstanding amounts due to it
under the Credit Agreement and all of its undrawn Commitments were cancelled (the Dexia Exit).
Consequently Dexia is no longer a Mandated Lead Arranger, Lender nor Swap Bank under the Credit
Agreement.
	 
	(C)	 	The Parties are entering into this Agreement to amend and restate the Credit Agreement




IT IS AGREED as follows:





	1.	 	DEFINITION AND INTERPRETATION
	 
	1.1	 	In this Agreement (including the recitals hereto) capitalised terms defined in the Amended and
Restated Credit Agreement have, unless specified, the same meaning when used in this Agreement,
and:
	 
	 	 	Amended and Restated Credit Agreement means the amended and restated Credit Agreement attached as
Schedule 4 hereto.
	 
	 	 	Documents has the meaning given in Schedule 2, Paragraph 6.
	 
	 	 	Effective Date means the date stated as such in the Effective Date Notice.
	 
	 	 	Effective Date Notice means a notice to be signed by the Facility Agent substantially in the form
set out in Schedule Schedule 3 (the Effective Date Notice).




1









 






	 	 	Parties means the parties to this Agreement.
	 
	1.2	 	Clause 1.2 of the Amended and Restated Credit Agreement shall be deemed to be part of this
Agreement and is hereby incorporated as if set out in full but with references therein to the
Amended and Restated Credit Agreement being replaced by references to this Agreement.
	 
	2.	 	AMENDMENT AND RESTATEMENT
	 
	(a)	 	The Parties each agree and acknowledge that on and from the Effective Date the Credit Agreement
will be amended and restated so that it takes effect in the form of the document as set out in
Schedule 4 (Amended and Restated Credit Agreement).
	 
	(b)	 	The Facility Agent shall serve the Effective Date Notice on the other parties to this Agreement
when it has received all of the conditions precedent set out in Schedule 2 in form and substance
satisfactory to the Facility Agent (acting on the instructions of all of the Lenders).
	 
	3.	 	FINANCE DOCUMENTS
	 
	3.1	 	This Agreement is a Finance Document for the purposes of the Amended and Restated Credit
Agreement.
	 
	3.2	 	The Parties each agree that on or after the Effective Date each reference in the Finance
Documents (other than in this Agreement) to the Credit Agreement (including the Schedules
(howsoever described)) shall be construed as a reference to that document as amended and restated
in accordance with the terms of Clause 2.
	 
	3.3	 	Save as expressly provided in this Agreement, each of the Parties confirms that each of the
Finance Documents to which it is a party remains in full force and effect.
	 
	4.	 	COUNTERPARTS
	 
	 	 	This Agreement may be executed in any number of counterparts. This has the same effect as if the
signatures on the counterparts were on a single copy of this Agreement.
	 
	5.	 	GOVERNING LAW
	 
	 	 	This Agreement and any non-contractual obligations arising out of or in connection with it, is
governed by and shall be construed in accordance with English law.
	 
	6.	 	JURISDICTION
	 
	6.1	 	The English courts have jurisdiction to settle any dispute in connection with this Agreement or
any non-contractual obligations in connection with it, and the Parties irrevocably submit to the
jurisdiction of the Courts of England and Wales, including in connection with any dispute relating to any non-contractual obligations arising out of or in
connection with this Agreement.
	 
	6.2	 	The English courts are the most appropriate and convenient courts to settle any such dispute in
connection with this Agreement. The Owner agrees not to argue to the contrary and waives objection
to those courts on the grounds of inconvenient forum or otherwise in relation to proceedings in
connection with this Agreement.
	 
	6.3	 	This Clause 6 is for the benefit of the Lenders and the Administrative Parties only. To the
extent allowed by law, the Lenders and the Administrative Parties may take:






	 	(a)	 	proceedings in any other court; and




2









 






	 	(b)	 	concurrent proceedings in any number of jurisdictions.






	6.4	 	References in this Clause 6 to a dispute in connection with this Agreement include any dispute
as to
the existence, validity or termination of this Agreement.
	 
	7.	 	SERVICE OF PROCESS
	 
	7.1	 	The Owner irrevocably appoints Ince Process Agents Ltd of International House, 5th Floor, 1st
Katherine’s Way, London, E1W lAY (attn: Mr. Michael Volikas) as its agent under this Agreement for
service of process in any proceedings before the English courts in connection with this Agreement.
	 
	7.2	 	If any person appointed as process agent under this Clause 7 is unable for any reason to act as
agent for service of process, the Owner must forthwith (and in any event within five (5) days of
the event taking place) appoint another agent on terms acceptable to the Facility Agent (acting
reasonably). Failing this, the Facility Agent may appoint another process agent for this purpose.
	 
	7.3	 	The Owner agrees that failure by a process agent to notify it of any process will not
invalidate the relevant proceedings.
	 
	7.4	 	This Clause 7 does not affect any other method of service allowed by law.
	 
	8.	 	WAIVER OF IMMUNITY






	 	The Owner irrevocably and unconditionally:
	 
	 	(a)	 	agrees not to claim any immunity from proceedings brought by a Finance Party against it in
relation to this Agreement and to ensure that no such claim is made on its behalf;
	 
	 	(b)	 	consents generally to the giving of any relief or the issue of any process in connection with
those proceedings; and
	 
	 	(c)	 	waives all rights of immunity in respect of it or its assets.




This Agreement has been entered into by the Parties on the day and year first above written.







3









 








SCHEDULE 1




ORIGINAL LENDERS


Deutsche Bank AG, London Branch



Eksportfinans ASA



The Export-Import Bank of Korea



DVB Bank N.V., Nordic Branch



Helaba Landesbank Hessen-Thüringen Girozentrale, New York Branch







4









 








SCHEDULE 2




CONDITIONS PRECEDENT




	1.	 	From and in relation to the Owner, the Parent, the Parent Shareholder and the Sponsor, refresh
certificates, update report or, as the case may be confirmation and satisfactory evidence of
continued compliance with the conditions precedent referred to in part 1 of schedule 2 to the
Credit Agreement at paragraphs 1,2,3, 18, 19 and 21.
	 
	2.	 	An up-to-date certificate of good standing of Ocean Rig dated no more than two Business Days
prior to the Effective Date and certified copies of its certificate of incorporation and
constitutional documents.
	 
	3.	 	A certified copy of a resolution of the board of directors of each of the Owner, the Parent, the
Parent Shareholder, the Sponsor and Ocean Rig:






	 	(a)	 	approving the terms of, and the transactions contemplated by, each Document to which it is a
party (and in the case of Ocean Rig, additionally the Petrobras Charter) and resolving that it
executes each such Document then to be executed;
	 
	 	(b)	 	authorising a specified person or persons to execute on its behalf each Document to which it is
a party (and in the case of Ocean Rig, additionally the Petrobras Charter), then to be executed;
and
	 
	 	(c)	 	authorising a specified person or persons, on its behalf, to sign and/or despatch all other
documents and notices to be signed and/or despatched by it under or in connection with each
Document then to be executed (and in the case of Ocean Rig, additionally the Petrobras Charter),






	 	 	together with a certified copy of the related shareholder resolutions of each of those entities.






	4.	 	A power of attorney of each of the Owner, the Parent, the Parent Shareholder, the Sponsor and
Ocean Rig issued, and not amended or rescinded, authorising the execution by the attorneys named
therein of the relevant Documents to which that entity is a party.
	 
	5.	 	A specimen of the signature of each person authorised by the resolutions referred to in
paragraphs 3 and 4 above.
	 
	6.	 	An original of each of the following documents (the Documents) duly executed by the parties to
it:






	 	(a)	 	this Agreement;
	 
	 	(b)	 	the DPP Deed of Accession;
	 
	 	(c)	 	the Ocean Rig Guarantee; and
	 
	 	(d)	 	the Confirmatory Charge.






	 	 	together with all notices and acknowledgements thereto.






	7.	 	A certified copy of the Petrobras Charter.
	 
	8.	 	Evidence that the amounts to be paid into:




5









 












	 	(a)	 	the Equity Account pursuant to clause 12.2(iii)(C) of the Amended and Restated Credit
Agreement; and
	 
	 	(b)	 	the Debt Service Reserve Account pursuant to clause 12.8(a) of the Amended and Restated Credit
Agreement,






	 	 	have been paid.






	9.	 	Evidence in connection with the Dexia Exit that the Swap Agreement between the Owner and Dexia
has been terminated, such that the aggregate Notional Amounts under, and as defined in, the Swap
Agreements following the Dexia Exit will not exceed the proportion of principal due under the
Amended and Restated Credit Agreement.
	 
	10.	 	Evidence of appointment of process agent by each of Ocean Rig, the Owner, the Parent, the
Parent Shareholder and the Sponsor in relation to each of the Documents to which it is a party.
	 
	11.	 	Legal opinions from:






	 	(a)	 	Allen & Overy LLP, London in relation to matters of English law; and
	 
	 	(b)	 	Seward & Kissel LLP, in relation to Ocean Rig, the Owner, the Parent, the Parent Shareholder,
the Sponsor and matters of Marshall Islands law.






	12.	 	A legal opinion from Allen & Overy LLP, English legal advisers to GIEK, addressed to
Eksportfinans and concerning certain provisions of the GIEK Guarantee.




6









 











SCHEDULE 3




FORM OF EFFECTIVE DATE NOTICE


Amendment and Restatement Agreement in relation to a credit agreement (the Agreement) dated 18 July
2008 as amended from time-to-time in respect of the drillship under construction with Hull Number
1865 (the Amendment and Restatement Agreement).



We refer to the Amendment and Restatement Agreement. Terms not defined herein are as defined in the
Amendment and Restatement Agreement.



Pursuant to clause 2 of the Amendment and Restatement Agreement, we hereby confirm that the
conditions precedent set out in Schedule 1 (Conditions Precedent) to the Amendment and Restatement
Agreement have been satisfied. Accordingly, the Effective Date shall be [ •  ] 2011.




For and on behalf of

Deutsche Bank Luxembourg S.A.

in its capacity as Facility Agent



By:



Title:







7









 








SCHEDULE 4




AMENDED AND RESTATED CREDIT AGREEMENT



8









 





EXECUTION VERSION




CREDIT FACILITY AGREEMENT



18 JULY 2008



DRILLSHIP KITHIRA OWNERS INC.

as Owner



DEUTSCHE BANK AG, LONDON BRANCH

as Bookrunner and Mandated Lead Arranger



VARIOUS FINANCIAL INSTITUTIONS

as Lenders



DEUTSCHE BANK AG, LONDON BRANCH

as Swap Bank



and



DEUTSCHE BANK LUXEMBOURG S.A.

as Facility Agent



and



DEUTSCHE BANK AG FILIALE DEUTSCHLANDGESCHAFT

as Security Trustee



as amended and supplemented from time-to-time



and as most recently amended and restated on April 2011



ALLEN & OVERY



Allen & Overy LLP



 









 





CONTENTS




	 	 	 	 	 
	Clause	 	Page	 
	1. Interpretation
	 	 	1	 
	2. Facilities
	 	 	30	 
	3. Conditions Precedent
	 	 	31	 
	4. Utilisation
	 	 	32	 
	5. Repayment
	 	 	36	 
	6. Prepayment and Cancellation
	 	 	36	 
	7. Interest
	 	 	41	 
	8. Terms
	 	 	42	 
	9. Market Disruption
	 	 	43	 
	10. Taxes
	 	 	44	 
	11. Increased Costs
	 	 	46	 
	12. Accounts
	 	 	47	 
	13. Payments
	 	 	52	 
	14. Representations and Warranties
	 	 	55	 
	15. Information Covenants
	 	 	62	 
	16. General Covenants
	 	 	67	 
	17. Insurances
	 	 	82	 
	18. Default
	 	 	87	 
	19. Security
	 	 	92	 
	20. The Administrative Parties
	 	 	93	 
	21. Evidence and Calculations
	 	 	98	 
	22. Fees
	 	 	98	 
	23. Indemnities and Break Costs
	 	 	99	 
	24. Expenses
	 	 	102	 
	25. Waiver of Consequential Damages
	 	 	103	 
	26. Amendments and Waivers
	 	 	103	 
	27. Changes to the Parties
	 	 	105	 
	28. Disclosure of Information
	 	 	107	 
	29. Set-Off
	 	 	108	 
	30. Pro Rata Sharing
	 	 	108	 
	31. Severability
	 	 	109	 
	32. Counterparts
	 	 	109	 
	33. Notices
	 	 	109	 
	34. Language
	 	 	111	 
	35. Governing Law
	 	 	111	 
	36. Enforcement
	 	 	111	 






 









 






	 	 	 	 	 
	Schedule	 	Page	 
	1. Original Lenders
	 	 	113	 
	2. Conditions Precedent
	 	 	114	 
	Part 1 Incidental Costs Loan
	 	 	114	 
	Part 2 Instalment Loan 1
	 	 	117	 
	Part 3 Instalment Loan 2
	 	 	118	 
	Part 4 Instalment Loan 3
	 	 	119	 
	Part 5 Delivery Loan
	 	 	120	 
	Part 6 Incidental Vessel Costs Loan
	 	 	123	 
	3. Form of Request
	 	 	124	 
	4. Form of Transfer Certificate
	 	 	126	 
	5. Loan Repayment Schedule
	 	 	128	 
	6. Calculation Certificate
	 	 	130	 
	7. Incidental Vessel Costs
	 	 	131	 
	8. Calculation of the Mandatory Cost
	 	 	132	 
	 
	 	 	 	 
	Appendix
	 	 	 	 
	 
	 	 	 	 
	1. Form of Delivery General Assignment
	 	 	134	 
	2. Form of Mortgage
	 	 	135	 
	3. Form of Charter Assignment
	 	 	136	 
	4. Approved Budget
	 	 	137	 
	 
	 	 	 	 
	Signatories
	 	 	138	 






 









 





THIS AGREEMENT is dated 18 July 2008, as amended and supplemented from time to time and as most
recently amended and restated on  April 2011




BETWEEN:





	(1)	 	DRILLSHIP KITHIRA OWNERS INC. a corporation incorporated in the Marshall Islands with
registered address at Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall
Islands MH 96960 as borrower (the Owner);
	 
	(2)	 	DEUTSCHE BANK AG, LONDON BRANCH as bookrunner and mandated lead arranger and bookrunner (in
this capacity the Bookrunner and Mandated Lead Arranger);
	 
	(3)	 	THE FINANCIAL INSTITUTIONS listed in Schedule 1 (Original Lenders) as original lenders (the
Original Lenders);
	 
	(4)	 	DEUTSCHE BANK AG, LONDON BRANCH as swap bank (in this capacity a Swap Bank);
	 
	(5)	 	DEUTSCHE BANK LUXEMBOURG S.A. as facility agent (in this capacity the Facility Agent); and
	 
	(6)	 	DEUTSCHE BANK AG FILIALE DEUTSCHLANDGESCHAFT as security trustee (in this capacity the Security
Trustee).




IT IS AGREED as follows:





	1.	 	INTERPRETATION
	 
	1.1	 	Definitions
	 
	 	 	In this Agreement:
	 
	 	 	Account Bank means Deutsche Bank AG (acting through its London branch) or any other bank or
financial institution which replaces the Account Bank in accordance with clause 13 of the DPP.
	 
	 	 	Account Bank Mandate means, in relation to any Account (other than the Equity Account), the
resolutions, instructions and signature authorities relating to such Accounts as will be agreed by
the Account Bank, the Owner and the Security Trustee on or prior to the Utilisation Date for the
Incidental Costs Loan.
	 
	 	 	Accounts means together the Debt Service Reserve Account, the Proceeds Account, the Debt Service
Account, the CAPEX Account, the Equity Account and the Operating Expenses Account.
	 
	 	 	Accounts Charge Agreement means the charge document entered into by the Owner in favour of the
Security Trustee in respect of the Accounts (other than the Equity Account) and dated 18 July 2008.
	 
	 	 	Act means the Law of Property Act 1925.
	 
	 	 	Administrative Party means the Facility Agent or the Security Trustee.
	 
	 	 	Affiliate means a Subsidiary or a Holding Company of a person or any other Subsidiary of that
Holding Company.




1









 






	 	 	Agreement means this credit facility agreement, including any schedules or appendices hereto, as
amended from time to time.
	 
	 	 	Amendment and Restatement Agreement means the amendment and restatement agreement dated April 2011
between, amongst others, the Owner, the Lenders, the Facility Agent and the Security Trustee to
which this Agreement is attached as schedule 4.
	 
	 	 	Amendment and Restatement Effective Date means the date specified as such in the effective date
notice issued pursuant to clause 2(b) of the Amendment and Restatement Agreement.
	 
	 	 	Annual Budget means a budget itemising:






	 	(a)	 	during the Pre-Completion Period, the Contract Price, the Incidental Costs, any other costs
approved by the Lenders and any other costs and expenses incurred or to be incurred in relation to
the construction of the Vessel and containing sufficient information and details to enable the
Equity Collateral to be calculated; and
	 
	 	(b)	 	during the Post-Completion Period:






	 	(i)	 	the anticipated Earnings;
	 
	 	(ii)	 	the anticipated Operating Expenses; and
	 
	 	(iii)	 	the anticipated CAPEX Expenses,






	 	 	in each case of the Owner for a financial year of the Owner agreed by the board of directors of the
Owner (based on the good faith estimates of the officers of the Owner and the Manager) and approved
by the Facility Agent in accordance with Clause 15.3 (Annual Budget and reports).
	 
	 	 	Applicable Law means any or all applicable law (whether civil, criminal or administrative), common
law, statute, statutory instrument, treaty, convention, regulation, directive, by-law, demand,
decree, ordinance, injunction, resolution, order, judgment, rule, permit, licence or restriction
(in each case having the force of law) and codes of practice or conduct, circulars and guidance
notes generally accepted and applied by the global off-shore oil-rig industry, in each case of any
government. quasi-government. supranational. federal, state or local government, statutory or
regulatory body, court, agency or association relating to all laws, rules, directives and
regulations, national or international, public or private in any applicable jurisdiction from time
to time.
	 
	 	 	Applicable Margin means, in respect of the KEXIM Loans or, as the case may be, the Commercial
Loans:






	 	(a)	 	during the Pre-Completion Period, the Pre-Completion Margin; or
	 
	 	(b)	 	during the Post-Completion Period, the Post-Completion Margin,






	 	 	as the case may be.
	 
	 	 	Approved Brokers means R.S. Platou Offshore, ODS Petrodata, H. Clarksons & Co Ltd. and Fearnley
Offshore AS, or such other brokers as may be approved by the Facility Agent and the Owner in
writing.




2









 






	 	 	Approved Budget means an Annual Budget approved by the Facility Agent in accordance with Clause
15.3 (Annual Budget and reports), the first such Annual Budget (covering the Pre-Completion Period)
being attached as Appendix 12.
	 
	 	 	Approved Incidental Vessel Costs means the costs of any of the types set out in Schedule 7 up to
the amounts for such costs specified in the budget for the project of constructing the Vessel
approved by the Facility Agent.
	 
	 	 	Availability Period means:






	 	(a)	 	for the Incidental Costs Loan, the Incidental Costs Loan Availability Period;
	 
	 	(b)	 	for the Instalment Loan 1, the Instalment Loan 1 Availability Period;
	 
	 	(c)	 	for the Instalment Loan 2, the Instalment Loan 2 Availability Period;
	 
	 	(d)	 	for the Instalment Loan 3, the Instalment Loan 3 Availability Period;
	 
	 	(e)	 	for the Delivery Loan, the period from and including the Delivery Date to and including the
earlier of:






	 	(i)	 	the Final Completion Date; and
	 
	 	(ii)	 	the Longstop Date;






	 	(f)	 	for the Undrawn Amount Loan, the period from and including the date falling ten (10) Business
Days after the Final Completion Date to and including the date falling thirty (30) Business Days
after the Final Completion Date; and
	 
	 	(g)	 	for an Incidental Vessel Costs Loan, the period from and including the date of this Agreement
to and including the Final Completion Date.






	 	 	Balancing Equity Contribution means the amount (if positive) at that time equal to:






	 	(a)	 	the aggregate of all costs payable or reasonably expected to be payable by the Owner to the
Builder under the Shipbuilding Contract; less
	 
	 	(b)	 	the aggregate of the Expected Contract Price and any Balancing Equity Contributions already
paid by the Owner into the Proceeds Account in accordance with Clause 12.2 (Proceeds Account).






	 	 	Basel Accord means the accord on minimum capital requirements for internationally active banks
promulgated in 1988 by the Basel Committee on Banking Supervision as amended prior to the date of
this Agreement.
	 
	 	 	Basel 11 means the revision to the Basel Accord as contemplated by the revised framework entitled
“International Convergence of Capital Measurement and Capital Standards: a Revised Framework”
published by the Basel Committee on Banking Supervision on 26 June 2004, as such revision may be
implemented in the United Kingdom, the EEA and the EU (including, for the avoidance of doubt, by
way of changes to the EU Capital Adequacy Directive).
	 
	 	 	Break Costs has the meaning given to such term in Clause 23.4(b) (Break Costs) or, in respect of an
Eksportfinans Lender, Clause 23.4(c) (Break Costs), or in respect of any Swap Bank, Clause 23.4(d)
(Break Costs).




3









 






	 	 	Builder means Samsung Heavy Industries Co., Ltd., a corporation incorporated in the Republic of
Korea with registered address at 34th Floor, Samsung Life Insurance Seocho Tower 1321-15,
Seocho-Dong, Seocho-Gu, Seoul, Korea 137-857.
	 
	 	 	Business Day means a day (other than a Saturday or a Sunday) on which banks are open for general
business in London, Luxembourg, Athens, Seoul, Oslo and New York.
	 
	 	 	Calculation Certificate means the calculation certificate referred to in Clause 15.11 (Calculation
Certificate) in the form set out in Schedule 6 (Calculation Certificate).
	 
	 	 	Calculation Period means:






	 	(a)	 	the period from (and including) the Final Completion Date of the Vessel to (and excluding) the
first Repayment Date; and
	 
	 	(b)	 	each subsequent period from (and including) a Repayment Date to (and excluding) the next
Repayment Date or, as the case may be, the Final Maturity Date.






	 	 	CAPEX Account means the bank account opened in the name of the Owner with the Account Bank and
designated “Kithira CAPEX Account.”
	 
	 	 	CAPEX Expenses means capital expenses incurred by the Owner in respect of the continued maintenance
and operation of the Vessel, including modifications required to be made to the Vessel by the
Classification Society or as required by Applicable Law.
	 
	 	 	Charter Assignment means, in respect of a Drilling Charter, the security agreement entered or to be
entered into in the form attached at Appendix 3 (Form of Charter Assignment) from the Owner, or
other counterparty to the Charterer under the Drilling Charter, to the Security Trustee in respect
of:






	 	(a)	 	its rights under that Drilling Charter; and
	 
	 	(b)	 	its rights under any applicable Charterer Parent Guarantee.






	 	 	Charter Termination Event means:






	 	(a)	 	any material breach by the Charterer of the terms of a Drilling Charter or, as applicable, by
the Charterer Parent of the terms of a Charter Parent Guarantee which material breach is not cured
by the date which falls 20 days after the date on which the Facility Agent gives written notice to
the Owner of the breach and such breach is not remedied, or otherwise compensated for, in each
case, to the satisfaction of the Majority Lenders within such period or if the matter has been
referred to arbitration within that 20 day period, upon the earlier of a settlement being reached
in respect of such arbitration and 15 days after the receipt of the final arbitration award; or
	 
	 	(b)	 	the termination of a Drilling Charter by the Owner or the Charterer.






	 	 	Charterer means any approved charterer of the Vessel under and in accordance with Clause 16.22
(Charters) or any replacement of such charterer in accordance with Clause 16.22(c) (Charters).
	 
	 	 	Charterer Parent means any person who as contemplated by Clause 16.22 (Charters) provides a
guarantee to the Owner in respect of a Charterer’s obligations under a Drilling Charter.




4









 






	 	 	Charterer Parent Guarantee means a guarantee, if any, from the Charterer Parent in form and
substance satisfactory to the Facility Agent (acting on the instructions of the Majority Lenders)
in favour of the Owner in respect of the Charterer’s obligations under a Drilling Charter.
	 
	 	 	Classification Society means American Bureau of Shipping or such other classification society
approved in writing by the Facility Agent (acting on the instructions of the Majority Lenders).
	 
	 	 	Commercial Lenders means the lenders detailed in Schedule 1 as Commercial Lenders together with any
New Lenders in respect of a Commercial Loan.
	 
	 	 	Commercial Loan means that portion of a Loan under the Facility (and identified as such in any
Request) advanced to the Owner by the Commercial Lenders.
	 
	 	 	Commitment means:






	 	(a)	 	for an Original Lender, the amount set opposite its name in Schedule 1 (Original Lenders) under
the heading “Commitments” and the amount of any other Commitment it acquires; and
	 
	 	(b)	 	for any other Lender, the amount of any other Commitment it acquires,






	 	 	to the extent not cancelled, transferred or reduced under this Agreement.
	 
	 	 	Confirmatory Charge means the confirmatory charge dated on or about the date of the Amendment and
Restatement Agreement entered into by the Owner, the Parent, the Parent Shareholder, Ocean Rig and
the Security Trustee relating to the Swap Agreement Assignment, the General Assignment, the Share
Charge, the Accounts Charge Agreement, the Management Agreement Assignment and the Floating Charge.
	 
	 	 	Construction Insurances means the construction insurances to be procured by the Builder under the
terms of Article XVII of the Shipbuilding Contract.
	 
	 	 	Contract Price means the lower of:






	 	(a)	 	the Expected Contract Price; and
	 
	 	(b)	 	the total amount actually paid to the Builder by or on behalf of the Owner under the
Shipbuilding Contract, as adjusted in accordance with the provisions of the Shipbuilding Contract.






	 	 	Date of Total Loss means, in respect of the Vessel, the date of Total Loss of the Vessel which date
shall be deemed to have occurred:






	 	(a)	 	in the case of an actual total loss, on the actual date and at the time the Vessel was lost or,
if such date is not known, on the date on which the Vessel was last reported;
	 
	 	(b)	 	in the case of a constructive total loss, upon the date and at the time notice of abandonment
is given to the Insurers for the time being (provided a claim for total loss is admitted by such
Insurers) or, if such Insurers do not forthwith admit such a claim, at the date and at the time at
which either a total loss is subsequently admitted by the Insurers or a total loss is subsequently
adjudged by a competent court of law or arbitration tribunal to have occurred;




5









 






	 	(c)	 	in the case of a compromised, agreed or arranged total loss, on the date upon which a binding
agreement as to such compromised, agreed or arranged total loss has been entered into by the
Insurers;
	 
	 	(d)	 	in the case of requisition for title or other compulsory acquisition, on the date upon which
the relevant requisition for title or other compulsory acquisition occurs; or
	 
	 	(e)	 	in the case of capture, seizure, arrest, detention, or confiscation of the Vessel by any
government or by persons acting or purporting to act on behalf of any government, government
authority or any other person or entity which deprives the Owner of the Vessel or, as the case may
be, the Charterer of the use of the Vessel for more than 60 days, upon the expiry of the period of
60 days after the date upon which the relevant capture, seizure, arrest, detention or confiscation
occurred.






	 	 	Debt Service Account means the bank account opened in the name of the Owner with the Account Bank
and designated “Kithira Debt Service Account”.
	 
	 	 	Debt Service means, in relation to any Calculation Period, an amount equal to the aggregate of:






	 	(a)	 	Financing Costs accruing; and
	 
	 	(b)	 	Financing Principal payable (other than as a result of a prepayment obligation),






	 	 	in that period less any amounts accruing for payment to the Owner in that period under a Swap
Agreement.
	 
	 	 	Debt Service Cover Ratio means, on any Repayment Date, the ratio of Net Cash Flow to Debt Service
for the Calculation Period ending on that Repayment Date.
	 
	 	 	Debt Service Reserve Account means the bank account in the name of the Owner with the Account Bank
and designated “Kithira Debt Service Reserve Account”.
	 
	 	 	Default means:






	 	(a)	 	an Event of Default; or
	 
	 	(b)	 	an event or circumstance which would be (with the expiry of a grace period, the giving of
notice or the making of any determination under the Finance Documents or any combination of them)
an Event of Default.






	 	 	Delivery Date means the date of actual delivery of the Vessel to the Owner under the terms of the
Shipbuilding Contract.
	 
	 	 	Delivery General Assignment means the assignment of the Requisition Compensation and the Obligatory
Insurances together with all benefits under the contracts, policies and
entries under the Obligatory Insurances and all claims in respect of them in substantially the form
of Appendix 1 (Form of Delivery General Assignment) (such form to be amended pursuant to Clause
16.36 (Delivery General Assignment) below) together with any and all notices and acknowledgements
entered into in connection therewith.
	 
	 	 	Delivery Loan means the Loan to be advanced under this Agreement on the Final Completion Date in
relation to the final Instalment.




6









 






	 	 	Deposit Bank means initially Deutsche Bank AG, London Branch or, as the case may be, any other bank
or financial institution substituting or replacing it pursuant to Clause 12.11 of this Agreement
or, as the case may be, clause 3.3 of the DPP.
	 
	 	 	Distribution means the payment by the Owner by way of any payment, repayment, redemption or
dividend, capital reduction, distribution or the like to any of its shareholders.
	 
	 	 	Dollars or US$ means the lawful currency for the time being of the United States of America.
	 
	 	 	DPP means the deed of proceeds and priorities between (inter alios) the Facility Agent, the
Security Trustee, the Owner, Ocean Rig, the Sponsor and the Swap Banks, dated 18 July 2008 and as
acceded to by Ocean Rig pursuant to the DPP Deed of Accession.
	 
	 	 	DPP Deed of Accession means the deed of accession to the DPP dated on or about the date of the
Amendment and Restatement Agreement, between, amongst others, the Facility Agent, the Security
Trustee, the Owner, the Sponsor, the Swap Bank and Ocean Rig and pursuant to which Ocean Rig became
a party to the DPP.
	 
	 	 	Drilling Charter has the meaning given to it in Clause 16.22(a).
	 
	 	 	Drilling Charter Final Period has the meaning given in Clause 16.33(a).
	 
	 	 	Earnings means all present and future moneys and claims which are earned by or become payable to or
for the account of the Owner in connection with the operation or ownership of the Vessel and
including but not limited to:






	 	(a)	 	freights, passage and hire moneys (howsoever earned), including, for the avoidance of doubt,
charterhire and charterhire performance bonuses payable under any Drilling Charter;
	 
	 	(b)	 	Liquidated Damages Payments;
	 
	 	(c)	 	remuneration for salvage and towage services;
	 
	 	(d)	 	demurrage and detention moneys;
	 
	 	(e)	 	all moneys and claims in respect of the requisition for hire of the Vessel;
	 
	 	(f)	 	payments received in respect of off-hire insurance; and
	 
	 	(g)	 	damages for breach or payments for termination of a Drilling Charter or any other contract for
the employment of the Vessel.






	 	 	Earnings Deposit Date shall have the meaning given to that term in Clause 12.3 (Transfers to the
Operating Expenses Account).
	 
	 	 	Eksportfinans means Eksportfinans ASA located at Postboks 1601 Vika, 0119, Oslo, Norway.
	 
	 	 	Eksportfinans CIRR means 3.93 per cent. per annum.
	 
	 	 	Eksportfinans Lenders means the lenders described in Schedule 1 as Eksportfinans Lenders together
with any New Lenders in respect of an Eksportfinans Loan.
	 
	 	 	Eksportfinans Loan means that portion of a Loan under the Facility (and identified as such in any
Request) advanced to the Owner by the Eksportfinans Lenders.




7









 






	 	 	Environment means:






	 	(a)	 	any land including, without limitation, surface land and sub-surface strata, sea bed or river
bed under any water (as referred to below) and any natural or man-made structures;
	 
	 	(b)	 	water including, without limitation, coastal and inland waters, surface waters, ground waters
and water in drains and sewers;
	 
	 	(c)	 	air including, without limitation, air within buildings and other natural or man-made
structures above or below ground; and
	 
	 	(d)	 	flora, fauna and ecological systems.






	 	 	Environmental Affiliate means the Owner, the Sponsor, Ocean Rig and the Manager together with their
respective officers, directors and employees and, during the Post-Completion Period, all of those
persons for whom the Owner, the Sponsor, Ocean Rig or the Manager is responsible under any
Applicable Law in respect of any activities undertaken in relation to the Vessel.
	 
	 	 	Environmental Approvals means any permit, licence, approval, consent, certificate, registration,
ruling, variance, exemption or other authorisation required under applicable Environmental Laws.
	 
	 	 	Environmental Claim means any claim by any person or persons or any governmental, judicial or
regulatory authority which arises out of any breach, contravention or violation of (or liability
under) Environmental Law, the existence of any liability arising from such breach, contravention or
violation, or the presence of or Release of any Hazardous Material. In this context, claim means: a
claim for damages, compensation, fines, penalties or any other payment of any kind whether or not
similar to the foregoing; an order or direction to take, or not to take, certain action or to
desist from or suspend certain action by any governmental, judicial or regulatory authority; and
any form of enforcement or regulatory action, but shall exclude a frivolous or vexatious claim
which is being contested in good faith and with due diligence and which is discharged or struck out
within 14 days.
	 
	 	 	Environmental Laws means any or all Applicable Law relating to or concerning:






	 	(a)	 	pollution or contamination of the Environment, including any remediation of any pollution or
contamination on the restoration or repair of any damage to the Environment:
	 
	 	(b)	 	the protection of the Environment and human health or safety or any living organisms which
inhabit the Environment or any ecological system;
	 
	 	(c)	 	the generation, manufacture, processing, distribution, use (including abuse), treatment,
storage, deposit, disposal, transport or handling of Hazardous Materials;
	 
	 	(d)	 	the Release or other form of transmission into the Environment of noise, vibration, dust,
fumes, gas, odours, smoke, steam, effluvia, heat, light, radiation (of any kind), infection,
electricity or any Hazardous Material and any matter or thing capable of constituting a nuisance or
an actionable tort or breach of statutory duty of any kind in respect of such matters; and
	 
	 	(e)	 	the provision and maintenance of bonds, guarantees or other forms of financial assurance
required by any Governmental Entity in connection with activities that could have an adverse effect
on the Environment.




8









 












	 	 	Equity Account means the bank account opened in the name of the Owner with the Equity Account Bank
and designated “Kithira Equity Account” for the purposes of the holding of the Equity Collateral.
	 
	 	 	Equity Account Bank means EFG Eurobank Ergasias S.A. or any other bank or financial institution
approved by the Facility Agent (acting on the instructions of the Majority Lenders).
	 
	 	 	Equity Account Charge means the charge document entered into by the Owner in favour of the Security
Trustee in respect of the Equity Account and dated 7 August 2008.
	 
	 	 	Equity Collateral means the cash security paid or to be paid by the Owner, or, as the case may be,
the Sponsor pursuant to Clause 12.2(a)(iii).
	 
	 	 	Equity Contribution means in respect of each Utilisation Date the amount required to be paid in
respect of Vessel Costs not funded by the Loan to be made on such date.
	 
	 	 	Event of Default means an event or circumstance specified as such in Clause 18 (Default) of this
Agreement.
	 
	 	 	Excess Risks means:






	 	(a)	 	the proportion of claims for general average, salvage and salvage charges which are not
recoverable as a result of the value at which the Vessel is assessed for the purpose of such claims
exceeding her hull and machinery insured value; and
	 
	 	(b)	 	collision liabilities not recoverable in full under the hull and machinery insurance by reason
of those liabilities exceeding such proportion of the insured value of the Vessel as is covered by
the hull and machinery insurance.






	 	 	Expected Contract Price means US$691,462,966 being the expected amount as at the date of this
Agreement payable by the Owner to the Builder under and in accordance with the terms of the
Shipbuilding Contract.
	 
	 	 	Facility means the term loan facility made available under this Agreement.
	 
	 	 	Facility Office means, in respect of a Lender, the office through which that Lender will perform
its obligations under this Agreement from time to time subject to Clause 27.5 (Costs resulting from
change of Lender or Facility Office).
	 
	 	 	Fee Letter means any letter entered into by reference to this Agreement between one or more
Administrative Parties, the Account Bank and/or the Mandated Lead Arranger and or any Lender and
the Owner (or Affiliate of the Owner or the Sponsor) setting out the amount of certain fees
relating to the Facility.
	 
	 	 	Final Completion Date means the later of:






	 	(a)	 	the date of actual delivery of the Vessel to the Charterer under the Drilling Charter and
unconditional acceptance by the Charterer under the terms thereof and
	 
	 	(b)	 	the date of confirmation to the Facility Agent from the Technical Adviser that the Vessels
design and performance fulfils the technical specifications required under the Shipbuilding
Contract and the Drilling Charter.




9









 












	 	 	Final Maturity Date means 31 December, 2020.
	 
	 	 	Finance Document means:






	 	(a)	 	this Agreement;
	 
	 	(b)	 	the Amendment and Restatement Agreement;
	 
	 	(c)	 	each Security Document;
	 
	 	(d)	 	the DPP;
	 
	 	(e)	 	the DPP Deed of Accession;
	 
	 	(f)	 	the GIEK Security Trustee Letter;
	 
	 	(g)	 	each Swap Agreement;
	 
	 	(h)	 	each Fee Letter;
	 
	 	(i)	 	each Transfer Certificate;
	 
	 	(j)	 	the Account Bank Mandate; and
	 
	 	(k)	 	any other document designated as such by the Facility Agent and the Owner.






	 	 	Finance Party means a Lender, a Swap Bank or an Administrative Party.
	 
	 	 	Financial Indebtedness means any indebtedness for or in respect of:






	 	(a)	 	moneys borrowed;
	 
	 	(b)	 	any amount raised by acceptance under any acceptance credit agreement (including any
dematerialised equivalent);
	 
	 	(c)	 	any amount raised pursuant to any note purchase facility or the issue of bonds, notes,
debentures, loan stock or other similar instrument;
	 
	 	(d)	 	any redeemable preference share;
	 
	 	(e)	 	the amount of any liability in respect of a lease or hire purchase contract which would, in
accordance with IFRS, be treated as a finance or capital lease;
	 
	 	(f)	 	receivables sold or discounted (otherwise than on a non-recourse basis);
	 
	 	(g)	 	the acquisition cost of any asset or service to the extent payable after its acquisition or
possession by the party liable where the advance or deferred payment is arranged primarily as a
method of raising finance or of financing the acquisition of that asset or service;
	 
	 	(h)	 	any derivative transaction protecting against or benefiting from fluctuations in any rate or
price (and, except for non-payment of an amount, the then mark to market value of the derivative
transaction will be used to calculate its amount);




10









 






	 	(i)	 	any amount raised under any other transaction (including any forward sale or purchase
agreement) which has the commercial effect of a borrowing other than trade credits incurred in the
ordinary course of business with credit terms of no longer than 90 days;
	 
	 	(j)	 	any counter-indemnity obligation in respect of any guarantee, indemnity, bond, letter of credit
or any other instrument issued by a bank or financial institution; or
	 
	 	(k)	 	the amount of any liability in respect of any guarantee, indemnity or similar assurance against
financial loss of any person in respect of any item referred to in the above paragraphs.






	 	Financing Costs means any of the following payable by the Owner:






	 	(a)	 	interest, fees and any other costs or expenses payable under the Finance Documents;
	 
	 	(b)	 	any Swap Costs; and
	 
	 	(c)	 	any Tax in respect of any of the above.






	 	 	Financing Principal means the amount of principal payable by the Owner in respect of the Loans from
time to time.
	 
	 	 	Five Year Drilling Charter means a Drilling Charter entered into in respect of the Vessel for a
minimum term (excluding any optional extensions) of five (5) years from the Final Completion Date.
	 
	 	 	Fixed Rate means the fixed rate of interest payable by the Owner to a Swap Bank under and in
accordance with the term, of a Swap Agreement.
	 
	 	 	Floating Charge means the charge document entered into by the Owner in favour of the Security
Trustee over all and any assets of the Owner and dated 6 August 2008.
	 
	 	 	Force Majeure Event means an event of force majeure as defined in or contemplated by Article III of
the Shipbuilding Contract or any event of force majeure as defined or contemplated by the Drilling
Charter.
	 
	 	 	General Assignment means the assignment of the Shipbuilding Contract, the Construction Insurances,
the Earnings and the Refund Guarantee, entered into by the Owner in favour of the Security Trustee
together with any and all notices and acknowledgements entered into in connection therewith and
dated 18 July 2008.
	 
	 	 	GIEK means Garanti Instituttet for Eksportkreditt of Dronning Mauds, gate 15, P.O. Box 1763 Vika
0122, Oslo, Norway.
	 
	 	 	GIEK Conditions means “GIEK’s Export Guarantees — General Conditions — Lenders Guarantee” and the
conditions set out in the GIEK Guarantee.
	 
	 	 	GIEK Guarantee means the buyer’s credit guarantee, including the GIEK Conditions, to be issued by
GIEK in favour of the Eksportfinans Lenders covering the Eksportfinans Loans.
	 
	 	 	GIEK Security Trustee Letter means the letter in the form attached at schedule 4 to the DPP.
	 
	 	 	Government Entity means, in respect of any country:






	 	(a)	 	any natural government, political subdivision thereof, or local jurisdiction therein; and




11









 






	 	(b)	 	any instrumentality, board, commission, court or agency thereof, however constituted.






	 	 	Gross Revenue means, for any Calculation Period, the aggregate Earnings received in such period in
respect of the Vessel.
	 
	 	 	Hazardous Material means any element or substance, whether natural or artificial, and whether
consisting of gas, liquid, solid or vapour, whether on its own or in any combination with any other
element or substance or radiation, which is listed, identified, defined or determined by any
Environmental Law or other Applicable Law as hazardous, harmful, a contamination or waste and or
capable of being or becoming harmful to mankind or any living organism or damaging to the
Environment, including, without limitation, oil (as defined in the United States Comprehensive
Environmental Response, Compensation and Liability Act of 1980, as amended, and the Oil Pollution
Act of 1990, as amended).
	 
	 	 	Hedged Portion means, from time to time, the principal amount of any outstanding Loans the interest
on which has been hedged by the Owner with a Swap Bank under and in accordance with the terms of
any Swap Agreement.
	 
	 	 	Holding Company means, in relation to a company or corporation, any company or corporation of which
it is a Subsidiary.
	 
	 	 	IFRS means the International Financial Reporting Standards issued by the board of the International
Accounting Standard Committee from time to time.
	 
	 	 	Incidental Costs means the Incidental Vessel Costs and the Incidental Loan Costs.
	 
	 	 	Incidental Costs Loan means the Loan, if any, to be advanced under the terms of this Agreement
during the Incidental Costs Loan Availability Period in relation to payment of Incidental Loan
Costs (other than interest and Commitment fees) and Incidental Vessel Costs in the maximum
principal amount specified in Clause 4.2(b).
	 
	 	 	Incidental Costs Loan Availability Period means the period from and including the date of this
Agreement to and including the earlier of (i) the Delivery Date and (ii) the Longstop Date.
	 
	 	 	Incidental Loan Costs means:






	 	(a)	 	each of the fees referred to in Clause 22 (Fees) and payable under the terms of the Fee Letters
during the Pre-Completion Period;
	 
	 	(b)	 	any and all costs and expenses which are payable by the Owner to the Secured Parties pursuant
to Clause 24.1 (Initial costs) within a period of three (3) months from the date of this Agreement;
and
	 
	 	(c)	 	interest in the Pre-Completion Period calculated and payable in accordance with Clause 7.1(a).






	 	 	Incidental Vessel Costs means, during the Pre-Completion Period:






	 	(a)	 	reasonable and properly incurred costs paid by the Owner in connection with the Vessel in
excess of the Contract Price, in respect of those items detailed in Schedule 7 (Incidental Vessel
Costs), for which supporting invoices or receipts have been provided to the Security Trustee;




12









 






	 	(b)	 	the Initial Debt Service Reserve Contribution; and
	 
	 	(c)	 	any interest accrued and payable to the Eksportfinans Lenders in respect of the Eksportfinans
Loans drawn under this Facility.






	 	 	Incidental Vessel Costs Loan means any Loan to be advanced under the terms of this Agreement in
relation to Incidental Vessel Costs.
	 
	 	 	Increased Cost means:






	 	(a)	 	an additional or increased cost;
	 
	 	(b)	 	a reduction in the rate of return from a Facility or on a Finance Party’s (or its Affiliate’s)
overall capital; or
	 
	 	(c)	 	a reduction of an amount due and payable under any Finance Document,






	 	 	which is incurred or suffered by a Finance Party or any of its Affiliates but only to the extent
attributable to that Finance Party having entered into any Finance Document or funding or
performing its obligations under any Finance Document.
	 
	 	 	Initial Debt Service Reserve Contribution means the payment to be made by the Owner or the Sponsor
to the Debt Service Reserve Account in accordance with Clause 12.8(a) (Payments to the Debt Service
Reserve Account prior to the Utilisation Date of the Delivery Loan) of this Agreement.
	 
	 	 	Initial Equity Contribution means US$99,150,000 to be contributed by the Sponsor to the Owner by
way of equity and to be paid to the Builder under the terms of the Shipbuilding Contract on or
prior to the Incidental Costs Loan Utilisation Date in satisfaction of the Instalments referred to
in Article II paragraphs 4(a)(i) to 4(a)(iii) inclusive of the Shipbuilding Contract.
	 
	 	 	Instalment means an amount due and payable by the Owner under the terms of the Shipbuilding
Contract.
	 
	 	 	Instalment Loan has the meaning given to it in Clause 4.1(c).
	 
	 	 	Instalment Loan 1 means the first Instalment Loan, if any, to be advanced under the terms of this
Agreement during the Instalment Loan 1 Availability Period in relation to the Instalment referred
to in Article II paragraph 4(b) of the Shipbuilding Contract.
	 
	 	 	Instalment Loan 2 means the second Instalment Loan, if any, to be advanced under the terms of this
Agreement during the Instalment Loan 2 Availability Period in relation to the Instalment referred
to in Article II paragraph 4(c) of the Shipbuilding Contract.
	 
	 	 	Instalment Loan 3 means the third Instalment Loan, if any, to be advanced under the terms of this
Agreement during the Instalment Loan 3 Availability Period in relation to the Instalment referred
to in Article II paragraph 4(d) of the Shipbuilding Contract.
	 
	 	 	Instalment Loan 1 Availability Period means the period from and including the date of this
Agreement to and including the earlier of(i) the Delivery Date and (ii) the Longstop Date.
	 
	 	 	Instalment Loan 2 Availability Period means the period from but excluding the Utilisation Date of
the Instalment Loan 1 to and including the earlier of (i) the Delivery Date and (ii) the Longstop
Date.




13









 






	 	 	Instalment Loan 3 Availability Period means the period from but excluding the Utilisation Date of
the immediately preceding Loan (if any) to and including the earlier of (i) the Delivery Date and
(ii) the Longstop Date.
	 
	 	 	Insurers means the underwriters or insurance companies with whom any Obligatory Insurances are
effected and the managers of any protection and indemnity or war risks association in which the
Vessel may at any time be entered.
	 
	 	 	Insurance Market Value means the fair market value of the Vessel, being the average of valuations
of the Vessel obtained from the Approved Brokers with or without physical inspection of the Vessel
(as the Security Trustee may reasonably require) on the basis of a sale for prompt delivery for
cash at arm’s length on normal commercial terms as between a willing buyer and a willing seller, on
an “as is, where is” basis, free of any existing charter or other contract of employment and or
pool arrangement.
	 
	 	 	ISM Code means the International Safety Management Code (including the guidelines on its
implementation) adopted by the International Maritime Organization Assembly as Resolutions
A.741(18) and A.788(19), as the same may have been or may be amended or supplemented from time to
time. The terms “safety management system”, “Safety Management Certificate”, “Document of
Compliance” and “major non-conformity” shall have the same meanings as are given to them in the ISM
Code.
	 
	 	 	ISPS Code means the International Ship and Port Facility Security Code adopted by the International
Maritime Organization Assembly as the same may have been or may be amended or supplemented from
time to time.
	 
	 	 	KEXIM means the Export Import Bank of Korea.
	 
	 	 	KEXIM Guarantee means the guarantee agreement to be issued by KEXIM in favour of the KEXIM Lenders
(other than KEXIM) covering the KEXIM Loan (other than that portion advanced by KEXIM itself).
	 
	 	 	KEXIM Lenders means the lenders detailed in Schedule 1 as KEXIM Lenders together with any New
Lenders in respect of a KEXIM Loan.
	 
	 	 	KEXIM Loan means that portion of a Loan under the Facility (and identified as such in any Request)
advanced to the Owner by the KEXIM Lenders.
	 
	 	 	Korea means the Republic of Korea.
	 
	 	 	Lender means:






	 	(a)	 	an Original Lender; or
	 
	 	(b)	 	any person which becomes a Party in accordance with Clause 27.2 (Assignments and transfers by
Lenders),






	 	 	and Lenders means all of them.
	 
	 	 	Leverage Ratio means, as at any date of determination, the ratio of the latest Market Value of the
Vessel (plus the value attributed to any additional security provided pursuant to Clause 16.33
(Leverage Ratio) as determined by the Facility Agent from time to time) to the aggregate principal
amount outstanding under the Facility.




14









 






	 	 	LIBOR means for a Term of any Loan or overdue amount:






	 	(a)	 	the applicable Screen Rate; or
	 
	 	(b)	 	if no Screen Rate is available for the relevant currency or for any Term of that Loan or
overdue amount, the arithmetic mean (rounded upward to four decimal places) of the rates, as
supplied to the Security Trustee at its request, quoted by the Reference Banks to leading banks in
the London interbank market,






	 	 	as of 11.00 a.m. on the second London Business Day before the start of the Term for the offering of
deposits in Dollars for a period comparable to that Term.
	 
	 	 	Liquidated Damages Payment means the amount of any liquidated damages payable to the Owner by the
Builder pursuant to Article III of the Shipbuilding Contract.
	 
	 	 	Loan means, unless otherwise stated in this Agreement, the principal amount of each borrowing under
this Agreement or the principal amount outstanding of that borrowing.
	 
	 	 	London Business Day means a day (other than a Saturday or a Sunday) on which banks are open for
business in London.
	 
	 	 	Longstop Date has the meaning given to that term in Clause 6.2(d) (Mandatory prepayment).
	 
	 	 	Losses means each and every liability, loss, charge, claim, demand, action, proceeding, damage,
judgment, order or other sanction, enforcement, penalty, fine, fee, commission, interest, lien,
salvage, general average, cost and expense of whatsoever nature suffered or incurred by or imposed
on any of the Finance Parties.
	 
	 	 	LTC Ratio means the ratio of all of the Loans to the aggregate of all of the Loans and the Sponsor
Equity, as in the formula:





            Σ Loans
       




Σ Loans + Sponsor Equity





	 	 	Maiden Voyage Costs means any costs of the Vessel incurred in respect of its maiden voyage from the
place of delivery under the Shipbuilding Contract to the first location provided for in a Drilling
Charter, including costs associated with positioning the Vessel for delivery under such Drilling
Charter.
	 
	 	 	Majority Lenders means Lenders:






	 	(a)	 	whose share in the outstanding Loans and whose undrawn Commitments then aggregate not less than
80% of the aggregate of all the outstanding Loans and the undrawn Commitments of all the Lenders
and who include at least (but without
limitation) one (1) Commercial Lender whose share in the outstanding Loans and whose undrawn
Commitments in connection with the Loans then aggregate more than 1% of the aggregate of all the
outstanding Loans and the undrawn Commitments of the Lenders; or
	 
	 	(b)	 	if there is no Loan then outstanding, whose undrawn Commitments then aggregate not less than
80% of the Total Commitments and who include at least (but without limitation) one (1) Commercial
Lender whose undrawn Commitments in connection with the Loans then




15









 






	 	 	 	aggregate more than 1% of the aggregate of all the undrawn Commitments of the Lenders; or
	 
	 	(c)	 	if there is no Loan then outstanding and the Total Commitments have been reduced to zero, whose
Commitments aggregated not less than 800o of the Total Commitments immediately before the reduction
and who include at least (but without limitation) one (1) Commercial Lender whose undrawn
Commitments in connection with the Loans aggregated more than 1% of the aggregate of all the
outstanding Loans and the undrawn Commitments of the Lenders,






	 	 	PROVIDED that for such purpose, and subject always to the further provisos below (i) each Lender
which has a separate participation in the Commercial Loans and or the Kexim Loans and or the
Eksportfinans Loans may vote its separate participation in each of such class of Loans as if it
were a separate Lender and (ii) each Lender may split its vote in relation to each such separate
participation in such proportions, as it, in its absolute discretion, determines, as if each such
proportion were held by a separate Lender AND PROVIDED FURTHER THAT the voting rights of the KEXIM
Lenders shall be exercised by KEXIM as if all such voting rights belonged to KEXIM.
	 
	 	 	Management Agreement means the management agreement in form and substance satisfactory to the
Facility Agent (acting on the instructions of the Majority Lenders) entered into between the
Manager and the Owner for the monitoring, organisation and supervision by the Manager in relation
to the project during the Pre-Completion Period and for the operation and servicing of the Vessel
during the Post-Completion Period and dated 1 August 2008.
	 
	 	 	Management Agreement Assignment means the assignment of the Management Agreement entered into by
the Owner in favour of the Security Trustee together with any and all notices and acknowledgments
entered into in connection therewith and dated 17 September 2008.
	 
	 	 	Manager means Ocean Rig AS (whether acting alone or through Cardiff Marine Inc. as provider of
certain administrative services) or such other person in each case approved by the Charterer from
time to time and the Facility Agent (acting on the instructions of the Majority Lenders).
	 
	 	 	Mandatory Cost means the percentage rate per annum calculated by the Facility Agent under Schedule
8 (Calculation of the Mandatory Cost).
	 
	 	 	Mandatory Prepayment Event means any of the events referred to in Clause 6 (Prepayment and
Cancellation) as a result of which the Owner is obliged to prepay any one or more of the Loans or
any Lender’s participation in the Loans.
	 
	 	 	Market Value means at any time the aggregate of:






	 	(a)	 	the net present value of the expected Net Cash Flow to be derived from each existing Drilling
Charter as calculated by the Facility Agent in its sole discretion on the basis of a discount rate
of 6 per cent. per annum and information then available to it and on the basis that:






	 	(i)	 	during the first year of each Drilling Charter the Operating Expenses shall be US$150,000 per
day and utilization rate of 95 per cent. for the Vessel; and
	 
	 	(ii)	 	thereafter the Operating Expenses and the utilization rate of the Vessel shall be the
Operating Expenses actually incurred and utilization rate actually achieved during the previous
twelve month period of the relevant Drilling Charter; and




16









 












	 	(b)	 	the forecasted fair market value of the Vessel derived from a valuation of the Vessel obtained
from one Approved Broker with or without physical inspection of the Vessel (as the Security Trustee
may reasonably require) on the basis of a sale for prompt delivery for cash at arm’s length on
normal commercial terms as between a willing buyer and a willing seller, on an “as is, where is”
basis, as at the latest expiry date of the then existing Drilling Charters.






	 	 	Material Adverse Effect means a material adverse effect on:






	 	(a)	 	the ability of the Owner, Ocean Rig or the Sponsor to perform its obligations under the
Transaction Documents;
	 
	 	(b)	 	the validity or enforceability of, or the effectiveness or ranking of any Security Interest
granted or purported to be granted pursuant to any Finance Document; or
	 
	 	(c)	 	any right or remedy of a Finance Party in respect of a Finance Document.






	 	 	Maximum Commercial Loan Amount means the lesser of (a) 16.7 per cent. of the Total Commitments and
(b) US$82,500,000.
	 
	 	 	Maximum Eksportfinans Loan Amount means the lesser of (a) 50.5 per cent. of the Total Commitments
and (b) US$250,000,000.
	 
	 	 	Maximum Facility Amount means the lower of (i) US$495,000,000 and (ii) an amount equal to 70°o of
the Vessel Cost.
	 
	 	 	Maximum KEXIM Loan Amount means the lesser of(a) 32.8 per cent. of the Total Commitments and (b)
US$162,500,000.
	 
	 	 	Moody’s means Moody’s Investor Services Inc. and any successor thereto.
	 
	 	 	Mortgage means the first preferred Marshall Islands ship mortgage to be given by the Owner in
favour of the Security Trustee on or prior to the Delivery Loan in the form attached at Appendix 2
(Form of Mortgage).
	 
	 	 	Net Cash Flow means, for any Calculation Period:






	 	(a)	 	Gross Revenues received; minus
	 
	 	(b)	 	Operating Expenses and CAPEX Expenses payable.






	 	 	Obligatory Insurances means all contracts and policies of insurance (other than the Contractor
Insurances) and all entries in clubs and or associations which are from time to time required to be
effected and maintained in accordance with Clause 17.1 (Scope of Obligatory Insurances) in respect
of the Vessel.
	 
	 	 	Ocean Rig means Ocean Rig UDW Inc. (previously named Primelead Shareholders Inc.) a corporation
incorporated in the Marshall Islands with its registered address at Trust Company Complex, Ajeltake
Road, Ajeltake Island, Majuro, Marshall Islands MH 96960.
	 
	 	 	Ocean Rig Guarantee means the guarantee and indemnity from Ocean Rig dated on or about the date of
the Amendment and Restatement Agreement, and in form and substance satisfactory to the Security
Trustee (acting on the instructions of all of the Lenders), pursuant to which Ocean Rig






17












 






	 	 	guarantees and indemnifies the Finance Parties in respect of the obligations of the Owner
under the Finance Documents during the Pre-Completion Period and the Post-Completion Period.
	 
	 	 	OECD means the Organisation for Economic Co-operation and Development.
	 
	 	 	Operating Expenses Account means the bank account opened in the name of the Owner with the Account
Bank and designated “Kithira Operating Expenses Account”.
	 
	 	 	Operating Expenses means expenses incurred by the Owner in connection with the transportation,
operation, employment, maintenance, repair, running and insurance of the Vessel, including
maintaining the ownership and legal fees, rentals, wages or fees which the Owner may be required to
pay pursuant to the Management Agreement, the cost of maintaining Obligatory Insurances and other
insurances maintained for the Vessel and payment of Tax properly payable by the Owner.
	 
	 	 	Operational Software means, at any time, any software which is then being used in connection with
the operation, navigation or maintenance of the Vessel.
	 
	 	 	Other Shipbuilding Contract means the turn key building contract between the Builder and the Other
Owner dated
17th September, 2007 pursuant to which the Builder agreed to build and deliver the
Other Vessel to the Other Owner.
	 
	 	 	Other Owner means Drillship Hydra Owners Inc.
	 
	 	 	Other Vessel means the drillship being constructed by the Builder for the Other Owner with Hull
Number 1837.
	 
	 	 	Owner’s Shipbuilding Contract Guarantee means the performance guarantee entered or to be entered
into in the form as set out in Exhibit 5 to the Shipbuilding Contract securing the obligations of
the Owner to the Builder under the Shipbuilding Contract.
	 
	 	 	Parent means Kithira Shareholders Inc., a corporation incorporated in the Marshall Islands and the
sole shareholder of the Owner whose registered office is at Trust Company Complex, Ajeltake Road,
Ajeltake Island, Majuro, Marshall Islands MH96960.
	 
	 	 	Parent Shareholder means Drillships Investment Inc., a corporation incorporated in the Marshall
Islands and the sole shareholder of the Parent whose registered office is at Trust Company Complex,
Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands MH96960.
	 
	 	 	Party means a party to this Agreement.
	 
	 	 	Permitted Liens means, in respect of any of the Security Assets:






	 	(a)	 	Security Interests created by the Security Documents;
	 
	 	(b)	 	liens for unpaid crew’s wages including wages of the master and stevedores employed by the
Vessel, outstanding in the ordinary course of business for not more than one month after the due
date for payment;
	 
	 	(c)	 	any Security Interest constituted by or securing any netting or set-off arrangement entered
into in the normal course of the Owner’s banking arrangements in respect of any bank accounts
opened by it and which have not been secured in favour of the Finance Parties pursuant to the
Security Documents;




18









 






	 	(d)	 	liens for salvage;
	 
	 	(e)	 	liens for classification or scheduled dry-docking or for necessary repairs to the Vessel whose
aggregate cost does not exceed US$10,000,000 at any one time in respect of the Vessel;
	 
	 	(f)	 	liens for collision;
	 
	 	(g)	 	liens for master’s disbursements incurred in the ordinary course of business;
	 
	 	(h)	 	statutory and common law liens of carriers, warehousemen, mechanics, suppliers, materials men,
repairers or other similar liens, including maritime liens, in each case arising in the ordinary
course of business, due and outstanding for not more than one month whose aggregate value does not
exceed US$10,000,000; and
	 
	 	(i)	 	any lien created or permitted to subsist with the prior written consent of the Security Trustee
(acting on instructions of the Majority Lenders),






	 	 	provided, in the case of paragraphs (b) to (h) inclusive, that the amounts which give rise to such
liens are paid when due or within any of the time periods stated above or within any applicable
grace period or, if not paid when due, are being disputed in good faith by appropriate proceedings
(and for the payment of which adequate reserves or security are at the relevant time maintained or
provided or for which indemnity or liability insurance cover for at least the full amount in
dispute (less any applicable deductible) has been obtained by the Owner from underwriters or
insurance companies that have been approved by the Facility Agent, (acting on the instructions of
the Majority Lenders)), provided further that such proceedings, whether by payment of adequate
security into Court or otherwise, do not give rise to a material risk of the Vessel or any interest
therein being seized, sold, forfeited or otherwise lost or of criminal liability on any Finance
Party.
	 
	 	 	Petrobras Charter means the agreement in respect of the Vessel for the provision of drilling
services with contract number 026-2010 between Petrobras Tanzania and Ocean Rig, dated 21 December
2010.
	 
	 	 	Petrobras Tanzania means Petrobras Tanzania Limited, a company incorporated under the laws of
Tanzania having its registered office at Plot 1403/1A Masaki Area, P.O. Box 31391 off Chole Rd.,
Behind Old Canada Village, Dar as Salaam, Tanzania.
	 
	 	 	Post-Completion Eksportfinans Interest Rate means the aggregate of the Eksportfinans CIRR and 1.61% per annum (being the post-completion GIEK-premium).
	 
	 	 	Post-Completion Margin means 1.75% per annum.
	 
	 	 	Post-Completion Period means the period from and including the Final Completion Date until and
including the Final Maturity Date.
	 
	 	 	Potential Mandatory Prepayment Event means any event which would be (with the expiry of a grace
period, the giving of notice or the making of any determination under the Finance Documents or any
combination of them) a Mandatory Prepayment Event.
	 
	 	 	Pre-Completion Eksportfinans Interest Rate means the
aggregate of the Eksportfinans CIRR and l.86%
(being the pre-completion GIEK-premium).
	 
	 	 	Pre-Completion Margin means 2.00% per annum.




19









 






	 	 	Pre-Completion Period means the period from and including the date on which the Incidental Costs
Loan is advanced under this Agreement to but excluding the Final Completion Date.
	 
	 	 	Pre-Delivery Period means the period from and including the date on which the Incidental Costs Loan
is advanced under this Agreement to but excluding the Delivery Date.
	 
	 	 	Primary Transfers has the meaning given to that term in Clause 12.2(f) (Proceeds Account).
	 
	 	 	Proceeds Account means the bank account in the name of the Owner with the Account Bank and
designated “ Kithira Proceeds Account”.
	 
	 	 	Project Parties means each of:






	 	(a)	 	the Owner, Ocean Rig and the Sponsor; and
	 
	 	(b)	 	from time to time, any of the Builder, the Manager, any Charterer Parent and/or Charterer (but
only to the extent, in any such case, that the same has or may in the future have, outstanding
liabilities owing to the Owner, Ocean Rig, the Sponsor or any Finance Party under any Finance
Document or Related Contract to which it is a party).






	 	 	Pro Rata Share means, in respect of a Lender:






	 	(a)	 	for the purpose of determining a Lender’s share in a utilisation of a Facility, the proportion
which its Commitment under that Facility bears to all the Commitments under that Facility; and
	 
	 	(b)	 	for any other purpose on a particular date:






	 	(i)	 	the proportion which a Lender’s share of the Loans (if any) bears to all the Loans;
	 
	 	(ii)	 	if there is no Loan outstanding on that date, the proportion which its Commitment bears to the
Total Commitments on that date; or
	 
	 	(iii)	 	if the Total Commitments have been cancelled otherwise, the proportion which its Commitments
bore to the Total Commitments immediately before being cancelled.






	 	 	Protocol of Delivery and Acceptance has the meaning given to such term in the Shipbuilding
Contract.
	 
	 	 	Rate Fixing Day means the date falling two London Business Days before the start of a Term for a
Loan or such other day as the Facility Agent determines is generally treated as the rate fixing day
by market practice in the relevant interbank market.
	 
	 	 	Receiver means an administrative receiver, receiver and manager or receiver in each case appointed
under a Security Document.
	 
	 	 	Reference Banks means the Facility Agent and any other bank or financial institution appointed as
such for the purpose of this Agreement by the Facility Agent in consultation with the Owner in
accordance with Clause 27.6 (Changes to the Reference Banks).
	 
	 	 	Refund Guarantee means the refund guarantee issued by the Refund Guarantor in favour of the Owner.
	 
	 	 	Refund Guarantor means the Export-Import Bank of Korea.




20









 






	 	 	Related Contracts means any or all of the following (as the context requires):






	 	(a)	 	the Refund Guarantee;
	 
	 	(b)	 	the Shipbuilding Contract;
	 
	 	(c)	 	the Other Shipbuilding Contract;
	 
	 	(d)	 	the Obligatory Insurances;
	 
	 	(e)	 	each Drilling Charter;
	 
	 	(f)	 	any Charterer Parent Guarantee;
	 
	 	(g)	 	the Management Agreement; and
	 
	 	(h)	 	the Sister Shipbuilding Contract.






	 	 	Release means an emission, spill, release or discharge into the Environment, including any release
falling within the definition ascribed to such term pursuant to the United States Comprehensive
Environmental Response, Compensation, and Liability Act of 1980, as amended.
	 
	 	 	Repayment Date means, subject to the provisions of Clause 5 (Repayment), each of the 18 dates which
fall at semi-annual intervals as detailed in the Repayment Schedule, the first such date falling
six months after the Final Completion Date and the final such date falling on the Final Maturity
Date.
	 
	 	 	Repayment Instalment means each scheduled instalment which is payable in accordance with the
Repayment Schedule.
	 
	 	 	Repayment Schedule means the schedule of repayment dates as detailed in Schedule 5 (Loan Repayment
Schedule), to be replaced as required in accordance with Clause 5 (Repayment) and Clause 6.9(b)
(Partial prepayment of Loans).
	 
	 	 	Repeating Representations means at any time the representations and warranties which are then made
or deemed to be repeated under Clause 14.30 (Times for making representations).
	 
	 	 	Request means a request made by the Owner for a Loan, substantially in the form of Schedule 3 (Form
of Request).
	 
	 	 	Required DSRA Balance means at any time the aggregate of:







	 	(a)	(i)	 	 until the date falling immediately prior to the first anniversary of the Utilisation Date
in respect of the Delivery Loan, the amount available to be transferred from the
Proceeds Account pursuant to Clause 12.8 (Payments to the Debt Service Reserve Account prior to the
Utilisation Date of the Delivery Loan) until such time as the balance thereof is the amount
referred to in (ii) below; and
	 
	 	 	(ii)	 	thereafter, the aggregate amount required to pay the next scheduled principal and interest
instalment under this Agreement on or before the next Repayment Date (with scheduled interest in
respect of any Hedged Portion being deemed to be payable at the applicable Fixed Rate); and






	 	(b)	 	the amount from time to time deposited pursuant to Clause 16.33(b)(ii) (Leverage Ratio).




21









 












	 	 	Required Insurance Amount means, on an agreed value basis, the higher of (a) 125% of the aggregate
of the outstanding Loans and (b) the Insurance Market Value of the Vessel.
	 
	 	 	Requisition Compensation means all moneys or other compensation payable by reason of requisition
for title to, or other compulsory acquisition of, the Vessel including requisition for hire.
	 
	 	 	Retention Period means each period commencing, in the case of the first such period, on (and
including) the Final Completion Date and ending on (but excluding) the first Repayment Date, in the
case of each other such period, on (and including) a Repayment Date and ending on (but excluding)
the next Repayment Date or, in the case of the final such period, the Final Maturity Date.
	 
	 	 	Required Prepayment Percentage means the sum expressed as a percentage of the following formula
(provided that if such sum is a negative figure, the sum shall be construed as zero):





	 	 	 

	(A x 0.6) — B

	 	x 100
	 	 	 

	C
	 	 







	 	 	where:






	 	A 	 	is the aggregate of B and C;
	 
	 	B 	 	is the amount of all of the Loans (as defined in the Sister Loan Agreement) outstanding under the
Sister Loan Agreement; and
	 
	 	C 	 	is the amount of all of the Loans outstanding under this Agreement.






	 	 	S&P means Standard & Poor’s Ratings Group and any successor thereto.
	 
	 	 	Scheduled Delivery Date means 31 July 2011.
	 
	 	 	Scheduled Instalment Amount means:






	 	(a)	 	for the Instalment payable on the Instalment Loan 1 Utilisation Date, the lower of 15.45% of
the Expected Contract Price and US$106,789,466;
	 
	 	(b)	 	for the Instalment payable on the Instalment Loan 2 Utilisation Date, the lower of 15.05% of
the Expected Contract Price and US$104,040,750;
	 
	 	(c)	 	for the Instalment payable on the Instalment Loan 3 Utilisation Date, the lower of 15.05% of
the Expected Contract Price and US$104,040,750;
	 
	 	(d)	 	for the Instalment payable on the Delivery Loan Utilisation Date, the lower of 40.125% of the
Expected Contract Price and US$277,442,000.






	 	 	Screen Rate means the British Bankers Association Interest Settlement Rate for the relevant
currency and Term displayed on the BBA Page LIBOR 01. If the relevant page is replaced or the
service ceases to be available, the Facility Agent may specify another page or service displaying
the appropriate rate after consultation with the Owner and the Lenders.
	 
	 	 	Secured Liabilities means all present and future obligations and liabilities (actual or contingent)
of the Owner, the Parent, the Parent Shareholder, the Sister Owner, the Sister Parent, Ocean Rig
and the Sponsor to the Secured Parties or any of them under or in connection with any Finance
Document or any Sister Finance Document.




22









 







	 	 	Secured Party means a Finance Party and any Sister Finance Party or GIEK.
	 
	 	 	Security Agreements means:






	 	(a)	 	the Mortgage;
	 
	 	(b)	 	the General Assignment;
	 
	 	(c)	 	the Share Charge;
	 
	 	(d)	 	the Share Charge Accession Deed;
	 
	 	(e)	 	the Sponsor Construction and Post-Delivery Guarantee;
	 
	 	(f)	 	the Sponsor Construction and Post-Delivery Guarantee Confirmation;
	 
	 	(g)	 	the Swap Agreement Assignment;
	 
	 	(h)	 	the Delivery General Assignment;
	 
	 	(i)	 	the Accounts Charge Agreement;
	 
	 	(j)	 	the Equity Account Charge;
	 
	 	(k)	 	the Charter Assignment;
	 
	 	(l)	 	the Management Agreement Assignment;
	 
	 	(m)	 	the Floating Charge;
	 
	 	(n)	 	the Ocean Rig Guarantee;
	 
	 	(o)	 	the Confirmatory Charge; and
	 
	 	(p)	 	any other document designated as such in writing by the Owner and the Facility Agent.






	 	 	Security Assets means any asset which is the subject of a Security Interest created by a Security
Document.
	 
	 	 	Security Document means:






	 	(a)	 	each Security Agreement; and
	 
	 	(b)	 	any other document evidencing or creating security over any asset of the Owner to secure any
obligation of the Owner to the Finance Parties or any of them under the Finance Documents.






	 	 	Security Interest means any mortgage, pledge, lien, charge, assignment, hypothecation or security
interest or any other agreement or arrangement having a similar effect.
	 
	 	 	Security Period means the period beginning on the date of the relevant Security Document and ending
on the date on which all the Secured Liabilities have been unconditionally and irrevocably paid,
performed and discharged in full.




23









 






	 	 	Share Charge means the charge in respect of the issued share capital of each of the Owner, the
Parent and the Parent Shareholder entered into or to be entered into on or prior to the Incidental
Costs Loan Utilisation Date and granted by each of the Parent, the Parent Shareholder and the
Sponsor, respectively, in favour of the Security Trustee dated 18 July 2008 as acceded to by Ocean
Rig pursuant to the Share Charge Accession Deed dated 19 March 2009.
	 
	 	 	Share Charge Accession Deed means the accession deed to the Share Charge between the Parent, the
Parent Shareholder, the Sponsor and Ocean Rig pursuant to which Ocean Rig became a party to the
Share Charge and dated 19 March 2009.
	 
	 	 	Shipbuilding Contract means the turn key building contract between the Builder and the Owner dated
as of 24 January 2008 (as may further be amended or supplemented from time to time) pursuant to
which the Builder agreed to build and deliver the Vessel to the Owner.
	 
	 	 	Sister Drilling Charter has the meaning given to the
term “Drilling Charter” in the Sister Loan
Agreement.
	 
	 	 	Sister Event of Default has the meaning given to the term “Event of Default” in the Sister Loan
Agreement.
	 
	 	 	Sister Finance Documents has the meaning given to the term “Finance Documents” in the Sister Loan
Agreement.
	 
	 	 	Sister Finance Party has the meaning given to the term “Finance Party” in the Sister Loan Agreement.
	 
	 	 	Sister Five Year Drilling Charter has the meaning
given to the term “Five Year Drilling Charter” in
the Sister Loan Agreement.
	 
	 	 	Sister Loan Agreement means the credit facility agreement entered into on 18 July 2008 as amended
and supplemented from time to time and as most recently amended and restated on or about the date
of the Amendment and Restatement Agreement between the Sister Owner, the Original Lenders as
lenders, the Security Trustee as security trustee and the Facility Agent as facility agent in
respect of the Sister Vessel.
	 
	 	 	Sister Owner means Drillship Skopelos Owners Inc., a company incorporated in the Marshall Islands
having its registered office at Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro,
Marshall Islands.
	 
	 	 	Sister Parent has the meaning given to the term “Parent” in the Sister Loan Agreement.
	 
	 	 	Sister Refund Guarantee means the refund guarantee issued by the Refund Guarantor in favour of the
Sister Owner.
	 
	 	 	Sister Security Trustee has the meaning given to the term “Security Trustee” in the Sister Loan
Agreement.
	 
	 	 	Sister Shipbuilding Contract means the turn key building contract between the Builder and the
Sister Owner dated as of 24 January 2008 pursuant to which the Builder agreed to build and deliver
the Sister Vessel to the Sister Owner.
	 
	 	 	Sister Three Year Drilling Charter has the meaning given to the term “Three Year Drilling Charter” in
the Sister Loan Agreement.




24









 






	 	 	Sister Vessel means the drillship being constructed by the Builder with Hull Number 1866 pursuant
to the Sister Shipbuilding Contract.
	 
	 	 	Software Licences means, at any time, all licences granted to the Owner in respect of the
Operational Software.
	 
	 	 	Software Records means, at any time, records in respect of:






	 	(a)	 	the Operational Software;
	 
	 	(b)	 	the identity of the then current suppliers of the Operational Software;
	 
	 	(c)	 	all upgrades carried out in respect of the Operational Software or changes to the Software
Licences; and
	 
	 	(d)	 	all Software Licences.






	 	 	Sponsor means Dryships Inc., a corporation incorporated in the Marshall Islands whose registered
office is at Trust Company Complex, Ajeltake Road, Ajeltake Island, Majuro, Marshall Islands
MH96960.
	 
	 	 	Sponsor Equity means the aggregate of any Balancing Equity Contribution, the Initial Equity
Contribution, the Equity Collateral and the Equity Contributions.
	 
	 	 	Sponsor Construction and Post-Delivery Guarantee means the guarantee and indemnity from the Sponsor
dated 18 July 2008 in favour of, and in form and substance satisfactory to, the Security Trustee
pursuant to which the Sponsor guarantees and indemnifies the Finance Parties in respect of the
obligations of the Owner to pay:






	 	(a)	 	the Initial Equity Contribution, each Equity Contribution (including any bonus payments to the
Builder if the Vessel is delivered early), the Equity Collateral, amounts to be paid into the Debt
Service Reserve Account and each Balancing Equity Contribution at the relevant time; and
	 
	 	(b)	 	during the Post-Completion Period, up to U.S.$2 14,000,000.






	 	 	Sponsor Construction and Post-Delivery Guarantee Confirmation means, in relation to the Sponsor
Construction and Post-Delivery Guarantee, written confirmation from the Sponsor contained in the
DPP Deed of Accession, that such guarantee is in full force and effect notwithstanding the
amendments contemplated by the Amendment and Restatement Agreement.
	 
	 	 	Subsidiary means:






	 	(a)	 	a subsidiary within the meaning of section 736 of the Companies Act 1985; and
	 
	 	(b)	 	unless the context otherwise requires, a subsidiary undertaking within the meaning of section
258 of the Companies Act 1985.






	 	 	Swap Agreement means any ISDA Master Agreement, schedule (including any credit support annexed
thereto) and any confirmations entered into between a Swap Bank and the Owner or any other hedging
arrangement entered into between a Swap Bank and the Owner prior to the Utilisation Date for the
Incidental Costs Loan in connection with at least 75 per cent. of the interest expected to




25









 












	 	 	be payable under this Agreement in respect of the KEXIM Loans and the Commercial Loans, as
estimated by the Swap Banks and as may be amended from time-to-time.
	 
	 	 	Swap Agreement Assignment means the assignment of certain Swap Agreements, entered into by the
Owner in favour of the Security Trustee and dated 6 August 2008.
	 
	 	 	Swap Bank means Deutsche Bank AG acting through its London branch (or any Affiliate thereof) and
from time to time, any person party to the DPP in its capacity as a swap bank.
	 
	 	 	Swap Costs means any amount payable by the Owner under a Swap Agreement except for any Swap
Termination Payment.
	 
	 	 	Swap Limit means US$40,000,000.
	 
	 	 	Swap Termination Payment means any sums payable or owing by the Owner to a Swap Bank under or in
connection with an Event of Default (as that term is defined in the relevant Swap Agreement) or
Termination Event (as that term is defined in the relevant Swap Agreement) or the occurrence of an
Early Termination Date (as that term is defined in the relevant Swap Agreement) pursuant to a Swap
Agreement whether or not matured and whether or not liquidated.
	 
	 	 	Tax means any tax, levy, impost, duty or other charge or withholding of a similar nature (including
any related penalty or interest payable in connection with any failure to pay or any delay in
paying any of the same).
	 
	 	 	Tax Deduction means a deduction or withholding for or on account of Tax made from a payment under a
Finance Document.
	 
	 	 	Tax Payment means a payment made by the Owner to a Lender in any way relating to a Tax Deduction or
under any indemnity given by the Owner in respect of Tax under any Finance Document.
	 
	 	 	Technical Adviser means Det Norske Veritas or any replacement marine surveyor, valuer or other
technical adviser appointed by the Facility Agent on behalf of the Lenders, in consultation with
the Owner, to review project progress on the Shipbuilding Contracts and Drilling Charter and to
report to the Lenders thereon.
	 
	 	 	Technical Proposal means the technical due diligence proposal dated 30 June 2008 and issued by the
Technical Adviser.
	 
	 	 	Technical Records means all technical data, manuals, logbooks and other records (whether kept or to
be kept in compliance with any Applicable Law or any requirement of any Government Entity or the
Drilling Charter) relating to the Vessel.
	 
	 	 	Term means each period determined under Clause 8 (Terms) by reference to which interest payable on
a Loan is calculated.
	 
	 	 	Three Year Drilling Charter means a Drilling Charter entered into for a minimum term (excluding any
optional extensions) of three (3) years, but less than five (5) years, from the Final Completion
Date.
	 
	 	 	Total Commitments means the aggregate of the Commitments of all the Lenders.
	 
	 	 	Total Loss means, in relation to the Vessel:




26









 












	 	(a)	 	actual, constructive, compromised, agreed or arranged total loss of the Vessel;
	 
	 	(b)	 	requisition for title or other compulsory acquisition of the Vessel otherwise than by
requisition for hire; and
	 
	 	(c)	 	capture, seizure, arrest, detention or confiscation of the Vessel by any Government Entity or
by persons acting or purporting to act on behalf of any government or any other person or entity
which deprives the Owner of the Vessel or, as the case may be, the Charterer of the use of the
Vessel for more than 60 days after that occurrence.






	 	 	Transaction Authorisation means any authorisation, permit, licence, consent or approval required by
any person or customary for any person to hold in connection with the entry into, performance,
validity and enforceability of, and the transactions contemplated by, the Transaction Documents,
excluding authorisations agreed not to be delivered under the Transaction Documents.
	 
	 	 	Transaction Documents means the Finance Documents and Related Contracts.
	 
	 	 	Transfer Certificate means a certificate, substantially in the form of Schedule 4 (Form of Transfer
Certificate), with such amendments as the Security Trustee and the Owner may approve or reasonably
require or any other form agreed between the Security Trustee and the Owner.
	 
	 	 	Undrawn Amount means an amount, determined as at the Final Completion Date, equal to the Maximum
Facility Amount less the aggregate of the Loans outstanding as at the Final Completion Date
following the advance of the Delivery Loan.
	 
	 	 	Undrawn Amount Loan means any Loan to be advanced under
the terms of this Agreement in relation to the Undrawn Amount.
	 
	 	 	Utilisation Date means each date on which a Facility or any part thereof is utilised.
	 
	 	 	Vessel means the drillship being constructed in accordance with the Shipbuilding Contract with Hull
Number 1865, including all the topside, equipment, buyer’s supplies, parts, material and items
constructed, manufactured or assembled under the Shipbuilding Contract incorporated in or attached
to it.
	 
	 	 	Vessel Cost means the total of (a) the Contract Price, (b) the Incidental Costs, and (c) any other
costs agreed by all of the Lenders.
	 
	 	 	Workscope means the workscope of the Technical Adviser as set out in the Technical Proposal.






	1.2	 	Construction






	 	(a)	 	In this Agreement, unless the contrary intention appears, a reference to:






	 	(i)	 	an amendment includes a supplement, novation, restatement or re-enactment and amended will be
construed accordingly;
	 
	 	(ii)	 	assets includes present and future properties, revenues and rights of every description;
	 
	 	(iii)	 	an authorisation includes an authorisation, consent, approval, resolution, licence,
exemption, filing, registration or notarisation;




27









 






	 	(iv)	 	disposal means a sale, transfer, grant, lease or other disposal, whether voluntary or
involuntary, and dispose will be construed accordingly;
	 
	 	(v)	 	indebtedness includes any obligation (whether incurred as principal or as surety) for the
payment or repayment of money;
	 
	 	(vi)	 	a person includes any individual, company, corporation, unincorporated association or body
(including a partnership, trust, joint venture or consortium), government, state, agency,
organisation or other entity whether or not having separate legal personality and shall include its
successors, permitted assignees and permitted transferees;
	 
	 	(vii)	 	a regulation includes any regulation, rule, official directive, request or guideline (whether
or not having the force of law but, if not having the force of law, being of a type with which any
person to which it applies is accustomed to comply) of any governmental, inter-governmental or
supranational body, agency, department or regulatory, self-regulatory or other authority or
organisation;
	 
	 	(viii)	 	know your customer requirements are the identification checks that a Finance Party requests
in order to meet its obligations under any Applicable Law to identify a person who is (or is to
become) its customer;
	 
	 	(ix)	 	a currency is a reference to the lawful currency for the time being of the relevant country;
	 
	 	(x)	 	a Default being outstanding or continuing means that it has not been cured, remedied or waived;
	 
	 	(xi)	 	a provision of law is a reference to that provision as extended, applied, amended or
re-enacted and includes any subordinate legislation;
	 
	 	(xii)	 	a Clause, a Subclause, an Appendix or a Schedule is a reference to a clause, subclause,
appendix of, or a schedule to, this Agreement;
	 
	 	(xiii)	 	a Party or any other person includes its successors in title permitted assigns and permitted
transferees;
	 
	 	(xiv)	 	a Finance Document, Sister Finance Document, other document or security includes (without
prejudice to any prohibition on amendments) any amendment to that Finance Document, Sister Finance
Document or other document or security, including any change in the purpose of, any extension of or
any increase in the amount of a facility or any additional facility;
	 
	 	(xv)	 	a time of day is a reference to London time; and
	 
	 	(xvi)	 	words importing the plural shall include the singular and vice versa.






	 	(b)	 	Unless the contrary intention appears, a reference to a month or months is a reference to a
period starting on one day in a calendar month and ending on the numerically corresponding day in
the next calendar month or the calendar month in which it is to end, except that:




28









 












	 	(i)	 	if the numerically corresponding day is not a Business Day, the period will end on the
next Business Day in that month (if there is one) or the preceding Business Day (if there is not);
	 
	 	(ii)	 	if there is no numerically corresponding day in that month, that period will end on the last
Business Day in that month; and
	 
	 	(iii)	 	notwithstanding subparagraph (i) above, a period which commences on the last Business Day of
a month will end on the last Business Day in the next month or the calendar month in which it is to
end, as appropriate.






	 	(c)	 	Unless expressly provided to the contrary in a Finance Document, a person (other than any
Secured Party or Affiliate of such Secured Party) who is not a party to a Finance Document may not
enforce any of its terms under the Contracts (Rights of Third Parties) Act 1999 and notwithstanding
any term of any Finance Document, no consent of any third party is required for any amendment
(including any release or compromise of any liability) or termination of that Finance Document.
	 
	 	(d)	 	Unless the contrary intention appears or unless the context otherwise permits:






	 	(i)	 	a reference to a Party will not include that Party if it has ceased to be a party under this
Agreement;
	 
	 	(ii)	 	a word or expression used in any other Finance Document or in any notice given in connection
with any Finance Document has the same meaning in that Finance Document or notice as in this
Agreement; and
	 
	 	(iii)	 	any obligation of the Owner under the Finance Documents which is not a payment obligation
remains in force in accordance with its terms for so long as any payment obligation of the Owner is
or may be outstanding under the Finance Documents.






	 	(e)	 	If, following the occurrence of an Event of Default which is continuing, any Finance Party
acting reasonably considers that an amount paid to it under a Finance Document is capable of being
avoided or otherwise set aside on the liquidation or administration of the payer or otherwise, then
that amount shall not be considered to have been irrevocably paid for the purposes of that Finance
Document.
	 
	 	(f)	 	The headings in this Agreement do not affect its interpretation.
	 
	 	(g)	 	Where the Owner requests any amendment, waiver or grace period in respect of any provision of
the Transaction Documents which would conflict with any provision of the GIEK Guarantee or require
consent from GIEK under the GIEK Guarantee, the Eksportfinans Lenders may request the Facility
Agent to ask GIEK for a response to such request and the Facility Agent shall not be obliged to
respond to the Owner until it receives a response from GIEK.
	 
	 	(h)	 	Where the Owner requests any amendment, waiver or grace period in respect of any provision of
the Transaction Documents which would conflict with any provision of the KEXIM Guarantee or require
consent from KEXIM, the KEXIM Lenders may request the Facility Agent to ask KEXIM for a response to
such request and the Facility Agent shall not be obliged to respond to the Owner until it receives
a response from KEXIM.




29









 












	2.	 	FACILITIES
	 
	2.1	 	Loan Facility






	 	(a)	 	Subject to the terms of this Agreement, the Lenders make available to the Owner a term loan
facility in a maximum aggregate amount equal to the Maximum Facility Amount.
	 
	 	(b)	 	The Facility shall be capable of being drawn up to the Maximum Facility Amount on the dates
described in Clause 4.2(a) (Completion of Requests).






	2.2	 	Purpose
	 
	 	 	Each Loan may be used only in or towards:






	 	(a)	 	financing or refinancing the cost of construction of the Vessel pursuant to the Shipbuilding
Contract;
	 
	 	(b)	 	financing such other items and costs as are included in the Vessel Cost; and
	 
	 	(c)	 	payment of amounts as described in Clause 4.1(e) (Giving of Requests).






	2.3	 	No obligation to monitor
	 
	 	 	No Finance Party is obliged to monitor or verify the utilisation of any Loan.






	2.4	 	Nature of a Finance Party’s rights and obligations






	 	(a)	 	Unless otherwise agreed in writing by all the Finance Parties:






	 	(i)	 	the obligations of a Finance Party under the Finance Documents are several;
	 
	 	(ii)	 	failure by a Finance Party to perform its obligations does not affect the obligations of any
other Party under the Finance Documents;
	 
	 	(iii)	 	no Finance Party is responsible for the obligations of any other Finance Party under the
Finance Documents;
	 
	 	(iv)	 	the rights of a Finance Party under the Finance Documents are separate and independent rights;
	 
	 	(v)	 	a Finance Party may, except as otherwise stated in the Finance Documents, separately enforce
those rights; and
	 
	 	(vi)	 	a debt arising under the Finance Documents to a Finance Party is a separate and independent
debt.






	 	(b)	 	If at any time a Finance Party fails to pay when due its share of any Loan amount when required
to do so, the Mandated Lead Arranger agrees that it shall consult with the Owner for a reasonable
period of time and act in good faith to assist the Owner in resolving the matter, but at all times
without any liability on the part of the Mandated Lead Arranger.
	 
	 	(c)	 	Each Swap Bank is a Party to this Agreement only in order to take the benefit of the rights
given to the Finance Parties by this Agreement.




30









 












	3.	 	CONDITIONS PRECEDENT






	3.1	 	Conditions precedent documents






	 	(a)	 	A Request in respect of any Loan may not be given until the Facility Agent has notified the
Owner and the Lenders that it has received all of the documents and evidence set out in Schedule 2
(Conditions Precedent) in respect of the Loan the subject of that Request in form and substance
satisfactory to the Facility Agent or that it expects to receive outstanding documents or evidence
on or before the Utilisation Date of such Loan or, in the case of evidence on the payment of the
Equity Contribution, Balancing Equity Contribution or Equity Collateral, on or before the date
which falls one (1) Business Day after the date of service of the relevant Request to the Facility
Agent (provided that it will be a condition precedent to the obligations of each Lender to advance
such Loan that, as at the relevant Utilisation Date (or, in the case of evidence of the payment of
the Equity Contribution, Balancing Equity Contribution or Equity Collateral, as at the date which
falls one (1) Business Day after the date the Request is served), such outstanding documents or
evidence have been received by the Facility Agent in form and substance satisfactory to the
Facility Agent. The Facility Agent must give this notification to the Owner and the Lenders
promptly upon being so satisfied.
	 
	 	(b)	 	That part of the Delivery Loan which relates to all or part of the Instalment payable on the
Delivery Date shall, if the Delivery Date has not at such time occurred, be deposited by the
Facility Agent into the account of [the Refund
Guarantor]1 (the Escrow Account) with its
correspondent bank in New York three Business Days prior to the proposed Delivery Date, subject to
the following irrevocable instructions (addressed to [the Refund Guarantor] with a copy to the
correspondent bank):






	 	 	“We have today credited to the account of [“The Export-Import Bank of Korea”] (account number [•] with
[•] ([here inset international recognition codes]) the amount of [insert here the amount of final
Loan to be used in respect of the Delivery Date Instalment] United States Dollars (US$[•]) (the
Deposit). This payment is made in connection with the delivery instalment which will become payable
by Drillship Kithira Owners Inc. (the Buyer) to Samsung Heavy Industries Co., Ltd. (the Builder)
under the terms of the shipbuilding contract dated 24th January 2008 relating to Hull no. 1865 (the
Ship). You are irrevocably instructed to order the release of the Deposit to either (a) the Builder
upon your receipt of both (i) a copy of the Protocol of Delivery and Acceptance relating to the
Ship signed by the Builder and the Buyer and (ii) a written confirmation from the Facility Agent
that the Deposit may be released to the Builder or (b) us (for credit to account number [•] to [•]
([here insert international recognition codes]) upon your receipt of written instructions from both
us and the Buyer to do so. If, by noon (Korean time) on the date which falls [5] days after the
proposed Delivery Date, you have not ordered the release of the Deposit to the Builder in
accordance with (a) above or to us in accordance with (b) above you shall (unless otherwise
instructed by us) immediately instruct the return of the Deposit to us (for credit to the account
referred to above) on and for value on the date which falls [5] days after the proposed Delivery
Date.”]






	 	(c)	 	If the Delivery Date has not occurred at the time the Request for the Delivery Loan is served,
the Owner undertakes with the Finance Parties not to sign a Protocol of Delivery and Acceptance in
respect of the Vessel unless the Facility Agent has confirmed that the conditions precedent
referred to in Clause 3.1(a) above in respect of the Delivery Loan above have been or will,
simultaneously with such signing, be satisfied.







 




			
	1  	 	Samsung to confirm—see Article II paragraph 5(c) of the Shipbuilding Contract.




31









 











	3.2	 	Further conditions precedent
	 
	 	 	The obligations of each Lender to advance any Loan are subject to the further conditions precedent
that on both the date of the Request and the Utilisation Date for that Loan:






	 	(a)	 	the Repeating Representations are correct in all material respects;
	 
	 	(b)	 	no Default or Mandatory Prepayment Event or Potential Mandatory Prepayment Event is outstanding
or would result from the Loan;
	 
	 	(c)	 	the Facility Agent has received an officer’s certificate from the Owner confirming that:






	 	(i)	 	save as permitted by the Finance Documents, there have been no material amendments or
variations agreed to the Related Contracts existing at such time that have not been agreed by the
Facility Agent in accordance with the terms of this Agreement;
	 
	 	(ii)	 	no Related Contracts have been rescinded or terminated by any party to them;
	 
	 	(iii)	 	no action has been taken by (a) the Owner (b) the Sponsor or (c) by any other party which
might in any way render any Related Contract inoperative or unenforceable, in whole or in any part;
and
	 
	 	(iv)	 	none of the events mentioned in Clauses 18.6 (Insolvency), 18.7 (Insolvency proceedings), 18.8
(Creditors’ process), 18.9 (Cessation of business), or 18.10 (Failure to pay final judgment) has
occurred, to the best of the Owner’s knowledge and belief (acting with the proper due diligence),
in respect of any of the Refund Guarantor, the Builder, the Manager, the Charterer Parent (if
applicable) or the Charterer (if applicable); and






	 	(d)	 	the Facility Agent has received such other documents which, based on legal advice received from
the relevant advisers referred to in this Agreement are necessary to evidence the legality,
validity and enforceability of the obligations of the parties to any Finance Document being
delivered on such Utilisation Date.






	3.3	 	Waiver of conditions precedent
	 
	 	 	The conditions precedent in this Clause 3 are solely for the benefit of the Lenders, and may be
waived on their behalf in whole or in part and with or without conditions by the Facility Agent
(acting on the instructions of all of the Lenders).






	4.	 	UTILISATION






	4.1	 	Giving of Requests






	 	(a)	 	The Owner may borrow a Loan by giving to the Facility Agent a duly completed Request.
	 
	 	(b)	 	Unless the Facility Agent otherwise agrees, the latest time for receipt by the Facility Agent
of a duly completed Request is 11.00 a.m. three Business Days prior to the date of the proposed
borrowing and, in respect of the Delivery Loan, ten Business Days prior to the date of the proposed
borrowing. The Owner undertakes that any advance notices regarding expected payment dates of
Instalments shall be promptly delivered to the Facility Agent at the same time as such notices are
received by the Owner, Manager or Sponsor, as the case




32









 












	 	 	 	may be, from the Builder. The Facility Agent shall provide copies of such advance notices promptly
to KEXIM upon receipt of the same from the Owner and to the other Lenders upon request.
	 
	 	(c)	 	The Owner may, subject to Clauses 4.1(d) and 4.1(e), submit up to only four Requests, one in
respect of each of the Instalment Loan 1, the Instalment Loan 2, the Instalment Loan 3, and the
Delivery Loan (each an Instalment Loan).
	 
	 	(d)	 	Notwithstanding Clause 4.1(c), the Owner may submit one Request for the Incidental Costs Loan
and Requests for Incidental Vessel Costs Loans in accordance with the provisions of Clause 4.2
(Completion of Requests).
	 
	 	(e)	 	Notwithstanding Clause 4.1(c), if on the Final Completion Date there is an Undrawn Amount, the
Owner may, if the Facility Agent (acting on the instructions of all the Lenders who shall have full
discretion in connection with such instructions) so agrees, and on such terms and subject to such
conditions as the Facility Agent may, acting on such instructions, require, submit a Request for an
amount not exceeding the Undrawn Amount to be used to reimburse the Owner for amounts of Vessel
Costs paid by it and not already financed hereunder or such other purposes as the Lenders may
agree.
	 
	 	(f)	 	Each Request is irrevocable.






	4.2	 	Completion of Requests
	 
	 	 	A Request will not be regarded as having been duly completed unless:






	 	(a)	 	the Utilisation Date is a Business Day falling within the relevant Availability Period for that
Loan and:






	 	(i)	 	for an Instalment Loan (other than the Delivery Loan), is the date on which the corresponding
Instalment is payable under the terms of the Shipbuilding Contract or, in the case of an Instalment
Loan which is to be used to refinance an Instalment, is a date after the date on which the Owner
has paid the corresponding Instalment to the Builder under the Shipbuilding Contract;
	 
	 	(ii)	 	for the Delivery Loan, is the Final Completion Date; or
	 
	 	(iii)	 	for an Incidental Vessel Costs Loan:






	 	(A)	 	for the first Incidental Vessel Costs Loan, is a date on or after the date of this Agreement;
and
	 
	 	(B)	 	for the second Incidental Vessel Costs Loan, is a date not earlier than 31 October 2008 and
for any other Incidental Vessel Costs Loan, is a date falling at least three (3) months after the
previous Incidental Vessel Costs Loan Utilisation Date






	 	(b)	 	the requested Incidental Costs Loan is in an amount not exceeding the aggregate amount of:






	 	(i)	 	the Incidental Loan Costs incurred in the period up to and including the Utilisation Date of
the Incidental Costs Loan;




33









 






	 	(ii)	 	the aggregate amount of the Approved Incidental Vessel Costs payable in the period up to
and including the Utilisation Date of the Incidental Costs Loan and supported by invoices or
receipts; and
	 
	 	(iii)	 	the aggregate estimated amount of Approved Incidental Vessel Costs which will become payable
in the period up to and including the Utilisation Date of the Instalment Loan 1, supported by
evidence satisfactory to the Facility Agent (acting in its sole discretion);






	 	(c)	 	the requested Loan (other than the requested Incidental Costs Loan) is in an amount not
exceeding:






	 	(i)	 	if either:






	 	(A)	 	the Petrobras Charter has been entered into at least ten (10) Business Days prior to the
relevant Utilisation Date; or
	 
	 	(B)	 	if a Drilling Charter and a Sister Drilling Charter has been entered into ten (10) Business
Days prior to the relevant Utilisation Date; and






	 	(I)	 	the Drilling Charter is a Five Year Drilling Charter and the Sister Drilling Charter is a
Sister Five Year Drilling Charter; or
	 
	 	(II)	 	the Drilling Charter is a Five Year Drilling Charter and the Sister
Drilling Charter is a Sister Three Year Drilling Charter; or
	 
	 	(III)	 	the Drilling Charter is a Three Year Drilling Charter and the Sister
Drilling Charter is a Sister Five Year Drilling Charter,






	 	 	 	a percentage of the Scheduled Instalment Amount or, as applicable the Approved Incidental Vessel
Costs (in each case determined by the Facility Agent) to be derived from an iterative process in a
manner that the expected LTC Ratio at the Utilisation Date following the advance of the Loan equals
zero point seven (0.7); or
	 
	 	(ii)	 	if the conditions in Clause 4.2(c)(i) have not been met, a percentage of the Scheduled
Instalment Amount or, as applicable the Approved Incidental Vessel Costs (in each case determined
by the Facility Agent) to be derived from an iterative process in a manner that the expected LTC
Ratio at the Utilisation Date following the advance of the Loan equals zero point four (0.4),






	 	 	 	together with the Incidental Loan Costs to be capitalised or, as the case may be, reimbursed on
that Utilisation Date in accordance with Clause 4.4; and
	 
	 	(d)	 	the amount requested for any Loan when aggregated with:






	 	(i)	 	existing Loans advanced by the Lenders;
	 
	 	(ii)	 	the amounts to be drawn down under any other Request issued for drawdown on the proposed
Utilisation Date; and






	 	(e)	 	all amounts capitalised pursuant to Clause 4.4, do not exceed the Maximum Facility Amount; and




34









 






	 	(f)	 	subject to Clause 4.3, the amount of the Loan requested is apportioned pro rata to the
Eksportfinans Loan, the KEXIM Loan and the Commercial Loan by reference to the proportion of the
Total Commitments borne by the Commitments of the Eksportfinans Lenders, the KEXIM Lenders and
Commercial Lenders respectively at the relevant time.






	 	 	Only one Loan may be requested in a Request.
	 
	4.3	 	Advance of Loan






	 	(a)	 	The Facility Agent must promptly notify each Lender of the details of the requested Loan and
the amount of its share in that Loan (as calculated by the Facility Agent in accordance with this
Clause 4.3).
	 
	 	(b)	 	No Eksportfinans Lender is obliged to participate in the Incidental Costs Loan or any
Incidental Vessel Costs Loan.
	 
	 	(c)	 	The amount of each Lender’s share of each requested Instalment Loan will be its Pro Rata Share
on the proposed Utilisation Date but adjusted so that the total amount lent by the Eksportfinans
Lenders in respect of such Loan is equal to the aggregate which would have been, and would be, lent
by the Eksportfinans Lenders, if:






	 	(i)	 	they had participated to the extent of their Pro Rata Share in the Incidental Costs Loan and
each Incidental Vessel Costs Loan drawn on or prior to the Utilisation Date of the relevant
Instalment Loan; and
	 
	 	(ii)	 	they were to participate to the extent of their Pro Rata Share in the relevant Instalment
Loan,






	 	 	 	and taking into account the amount actually lent by the Eksportfinans Lenders in respect of any
Instalment Loans for already drawn.
	 
	 	(d)	 	The Facility Agent shall calculate the amount to be lent by each of the Lenders in connection
with each Instalment Loan and shall notify each of the Lenders of such amount as soon as
practicable after receipt by the Facility Agent of the Request relating to that Instalment Loan.
	 
	 	(e)	 	No Lender is obliged to participate in a Loan if, as a result:






	 	(i)	 	its share in the Loans under the Facility would exceed its Commitment;
	 
	 	(ii)	 	the Loans would exceed the Total Commitments;
	 
	 	(iii)	 	in respect of the Eksportfinans Lenders, the aggregate of the Eksportfinans Loans would
exceed the Maximum Eksportfinans Loan Amount;
	 
	 	(iv)	 	in respect of the KEXIM Lenders, the aggregate of the KEXIM Loans would exceed the Maximum
KEXIM Loan Amount; or
	 
	 	(v)	 	in respect of the Commercial Lenders, the aggregate of the Commercial Loans would exceed the
Maximum Commercial Loan Amount;




35









 












	 	(f)	 	If the conditions set out in this Agreement have been met, each Lender must ensure that
its share in the requested Loan will be available to the Facility Agent for the Owner through its
Facility Office by 10.00 a.m. on the relevant Utilisation Date.






	4.4	 	Capitalisation of interest payable to Commercial Lenders and KEXIM Lenders






	 	(a)	 	During the Pre-Completion Period the Commitment fee payable in accordance with Clause 22.1
(Commitment fee), and interest calculated and payable in accordance with Clause 7.1 (a) and 7.1 (c)
(other than any such Commitment fees or interest included in the Incidental Costs Loan or interest
payable to the Eksportfinans Lenders under this Agreement) shall accrue and shall, on the last day
of each Term during the Pre-Completion Period, be capitalised and added to the principal amount of
the Loans outstanding.






	 	(b)	 	The amount of any Incidental Loan Costs to be capitalised may not in any circumstances exceed,
when aggregated with the Loans already made and amounts of Incidental Loan Costs already
capitalised under the relevant Loan, the Maximum Facility Amount or cause the applicable LTC Ratio
set out in Clause 4.2 (c) (i) or 4.2 (c) (ii) to be breached. Any Incidental Loan Costs due and
payable which cannot be capitalised in accordance with this Clause 4.4 must be paid by the Owner on
the due date.






	5.	 	REPAYMENT






	 	(a)	 	The Owner must repay the Loans to the Facility Agent on each Repayment Date in accordance with
the Repayment Schedule.
	 
	 	(b)	 	The Facility Agent shall notify the Owner and the Lenders of any change in the amount or the
timing of any Repayment Instalment as soon as practicable prior to or, as the case may be, after
the Final Completion Date. In the event of any such notification, the Facility Agent shall replace
the Repayment Schedule attached at Schedule 5 (Loan Repayment Schedule) with a new Repayment
Schedule reflecting the correct Repayment Instalments and the correct Repayment Dates and promptly
provide a copy thereof to the Owner and the Lenders.
	 
	 	(c)	 	The Loans shall be repaid in full on the Final Maturity Date.
	 
	 	(d)	 	Any amounts repaid under this Clause 5 may not be re-borrowed.






	6.	 	PREPAYMENT AND CANCELLATION
	 
	6.1	 	Mandatory prepayment — illegality






	 	(a)	 	If it becomes, or to the knowledge of any Lender is to become, unlawful or otherwise prohibited
(whether temporarily or permanently) in any jurisdiction for a Lender to perform any of its
obligations as contemplated by a Finance Document or to fund or maintain its share in one or more
of the Loans, or to exercise any of its material rights
under the Finance Documents, that Lender shall notify the Facility Agent and the Owner (any such
event being a Lender Event).
	 
	 	(b)	 	After notification under paragraph (a) above (and subject always to satisfactory alternate
arrangements being put into place in accordance with paragraph (d) below):






	 	(i)	 	the Owner must repay or prepay the share of that Lender in the relevant Loan or Loans on the
date specified in paragraph (c) below; and




36









 






	 	(ii)	 	the Commitments of that Lender will be immediately cancelled.






	 	(c)	 	The date for prepayment of a Lender’s share in a Loan will be:






	 	(i)	 	the last day of the current Term of that Loan; or
	 
	 	(ii)	 	if earlier, the date specified by that Lender in the notice delivered to the Owner under
paragraph (a) above (being no earlier than the last day of any applicable grace period permitted by
Applicable Law).






	 	(d)	 	If, prior to the occurrence of a Lender Event, a Lender receives notice or becomes aware that a
Lender Event will occur, that Lender and the Owner shall enter into discussions in good faith for a
period of twenty (20) days (or such shorter period, if any, as may be available prior to the Lender
Event taking effect) (the Lender Consultation Period) with a view to agreeing how the effects of
the Lender Event can be avoided or mitigated so that alternative legal, valid and binding
obligations, in form and substance satisfactory to that Lender and the Owner, are put in place. If
that Lender and the Owner cannot agree and complete such arrangements prior to the end of the
Lender Consultation Period, the Owner shall be obliged to immediately prepay the share of that
Lender in the Loan on the date specified in paragraph (c) above.






	6.2	 	Mandatory prepayment — Total Loss, sale and Related Contracts
	 
	 	 	The Owner shall be obliged to prepay the whole of the Loans then outstanding (and each Lender’s
Commitments shall be immediately cancelled) in the following circumstances and at the following
times:






	 	(a)	 	if there is a Total Loss (whether before or after the Delivery Date), on the earlier of:






	 	(i)	 	the date falling 90 days after the Date of Total Loss; and
	 
	 	(ii)	 	the date of receipt by the Owner or the Security Trustee of the proceeds of insurance relating
to such Total Loss;






	 	(b)	 	if the Owner fails to deliver the Vessel to the Charterer in accordance with the terms of a
Drilling Charter (other than in circumstances where there is a Charter Termination Event), on the
date of such failure;
	 
	 	(c)	 	if either the Builder or the Owner is in breach of any of its material obligations under the
Shipbuilding Contract, or either the Manager or the Owner is in breach of any of its material
obligations under any other Related Contract, on the date falling 20 days after the date on which
the Facility Agent gives written notice to the Owner that the Majority Lenders have so determined
and such breach is not remedied or otherwise compensated for, in each case, to the satisfaction of
the Majority Lenders within such period, or if the matter has been referred to arbitration within
that 20-day period, upon the earlier of a
settlement being reached in respect of such arbitration and 5 days after the receipt of the final
arbitration award;
	 
	 	(d)	 	if the Vessel has not been delivered by the Builder and accepted unconditionally by the
Charterer under the relevant Drilling Charter by the date falling 210 days after the Scheduled
Delivery Date (the Longstop Date), on the Business Day immediately succeeding the Longstop Date;




37









 






	 	(e)	 	if a material part of the assets of the Charterer or, if applicable, the Charterer Parent
are seized, expropriated, or compulsorily acquired, nationalised, confiscated or requisitioned by
any Government Entity or by persons purporting to act on behalf of any Government Entity, subject,
however, to the provisions of Clause 16.23 (Breach or Termination of Drilling Charter or Management
Agreement);
	 
	 	(f)	 	if a Charter Termination Event occurs, on the date of the occurrence of such Charter
Termination Event, subject, however, to the provisions of Clause 16.23 (Breach or Termination of
Drilling Charter or Management Agreement);
	 
	 	(g)	 	if the Vessel is sold, on or before the date on which the sale is completed;
	 
	 	(h)	 	if the Shipbuilding Contract is terminated in circumstances where the Refund Guarantee is
payable upon the earlier of:






	 	(i)	 	the date of receipt of the moneys under the Refund Guarantee; and






	 	(ii)	 	20 days after the date of termination or if the matter has been referred to arbitration within
that 20-day period, upon the earlier of a settlement being reached in respect of such arbitration
and 5 days after the receipt of the final arbitration award;






	 	(i)	 	if the Shipbuilding Contract is terminated in circumstances other than those referred to in
paragraph (c), on the date of its termination;
	 
	 	(j)	 	if either:






	 	(A)	 	the Owner ceases to be a Subsidiary of the Sponsor; or
	 
	 	(B)	 	Ocean Rig ceases to have direct or indirect control of the Owner or to own directly or
indirectly more than 50% of the voting capital or similar right of ownership of the Owner (and
control for this purpose means the power to direct the management and the policies of the Owner
whether through the ownership of voting capital, by contract or otherwise),






	 	 	 	in either case without the prior written consent of the Facility Agent (acting on the instructions
of all the Lenders). The Facility Agent agrees that it will consult with the Owner in good faith
(taking into account, inter alia, the security and credit position of the Finance Parties) should
the Owner, Ocean Rig or the Sponsor approach the Facility Agent with a proposal to effect an
initial public offering of the Owner (but without an obligation on the part of any of the Finance
Parties to consent to any such proposed initial public offering); or
	 
	 	(k)	 	if on or prior to the Delivery Date the obligations and requirements under Clause 16.35
(Petrobras Charter) below have not been satisfied.






	6.3	 	Mandatory prepayment amount — Sister Vessel
	 
	 	 	The Owner shall be obliged to prepay the Required Prepayment Percentage of each of the Loans then
outstanding (and each Lender’s Commitment shall be immediately pro rata cancelled) in the following
circumstances and at the following times:






	 	(a)	 	if the Sister Vessel is sold, on or before the date on which the sale is completed; or




38









 






	 	(b)	 	if Ocean Rig ceases, for whatever reason, to own or retain the legal and beneficial
interest in at least 50% of the shares of the Sister Owner.






	6.4	 	Mandatory Prepayment — Invalidity of Finance Documents or Related Contracts






	 	(a)	 	Without prejudice to the provisions of Clause 6.1 (Mandatory
prepayment-illegality), if the
Facility Agent or the Owner become aware that any of the following (an Invalidity Event) has
occurred or is likely to occur:






	 	(i)	 	any Finance Document or Related Contract or any material provision of any such document ceasing
to be valid in any way which, in the case of a Finance Document, is material and, in the case of a
Related Contract, in any way which has a Material Adverse Effect or is alleged by the Owner to be
ineffective in accordance with its terms for any reason;
	 
	 	(ii)	 	any Security Document creating a Security Interest in favour of the Security Trustee (on trust
for the Finance Parties) ceasing to provide a perfected first priority security interest in favour
of the Security Trustee (on trust for the Finance Parties) (subject to any Permitted Liens having
priority in law); or
	 
	 	(iii)	 	the Owner repudiates a Finance Document,






	 	 	then the Facility Agent or the Owner, as the case may be, shall as soon as practicable after
becoming aware thereof give each other notice of the same (an Invalidity Notice) and, subject to
paragraph (b) below, following receipt of an Invalidity Notice the Owner shall immediately prepay
the outstanding Loans together with accrued interest and all other amounts accrued under the
Finance Documents, and the Commitments of the Lenders shall be immediately cancelled.






	 	(b)	 	If, prior to the occurrence of an Invalidity Event, the Facility Agent or the Owner receives an
Invalidity Notice, the Facility Agent (acting on the instructions of the Majority Lenders) and the
Owner shall enter into discussions in good faith for a period of 20 days or such shorter period, if
any, as may be available prior to the Invalidity Event taking effect (the Consultation Period) with
a view to agreeing how the effects of the Invalidity Event can be avoided so that alternative
legal, valid and binding obligations, in form and substance satisfactory to the Facility Agent
(acting on the instructions of the Majority Lenders) are provided in replacement of the affected
Finance Document or Related Contract. In conducting such discussions and reaching a conclusion, the
Lenders shall act in good faith but otherwise in their absolute discretion. If the Facility Agent
(acting on the instructions of the Majority Lenders) and the Owner cannot agree on and complete
such arrangements prior to the earlier of the end of the Consultation Period and the date upon
which the relevant Invalidity Event becomes effective, the Owner shall be obliged to immediately
prepay all outstanding Loans together with accrued interest and all other amounts accrued under the
Finance Documents, and the Commitments of the Lenders shall be immediately cancelled.






	6.5	 	Voluntary prepayment






	 	(a)	 	The Owner may, at any time after the Final Completion Date and giving not less than 30 days’
prior written notice to the Facility Agent, prepay a Loan in whole or in part on the last day of
the relevant Term so long as it simultaneously (or if not then permitted on the earliest permitted
date) prepays a pro rata amount of the principal outstanding under the Sister Loan Agreement.




39









 






	 	(b)	 	A prepayment must be in a minimum amount of US$10,000,000 and, in excess of that, in
multiples of US$1,000,000.






	6.6	 	Automatic cancellation
	 
	 	 	The relevant Commitments of each Lender will be automatically cancelled at the close of business on
the last day of the relevant Availability Period.
	 
	6.7	 	Voluntary cancellation






	 	(a)	 	The Owner may, by giving not less than five Business Days’ prior notice to the Facility Agent,
cancel the unutilised amount of the Total Commitments in whole or in part so long as it cancels a
pro rata amount of commitments under the Sister Loan Agreement.
	 
	 	(b)	 	Partial cancellation of the Total Commitments must be in a minimum amount of US$10,000,000 and,
in excess of that, in multiples of US$1,000,000.
	 
	 	(c)	 	Any cancellation in part will be applied against the relevant Commitment of each Lender pro
rata and in respect of the Facility, across the Eksportfinans Loan, the KEXIM Loan and the
Commercial Loan pro rata.






	6.8	 	Voluntary prepayment and cancellation






	 	(a)	 	If the Owner is, or will be, required to pay to a Lender a Tax Payment or an Increased Cost,
the Owner may, while the requirement continues, give notice to the Facility Agent requesting
prepayment and cancellation in respect of that Lender.
	 
	 	(b)	 	After notification under paragraph (a) above:






	 	(i)	 	the Owner must repay or prepay that Lender’s share in each Loan made to it on the date
specified in paragraph (c) below; and
	 
	 	(ii)	 	the Commitment of that Lender will be immediately cancelled.






	 	(c)	 	The date for prepayment of a Lender’s share in a Loan will be the last day of the current Term
for the relevant Loan or any earlier date agreed between the Owner, the Facility Agent and that
Lender.






	6.9	 	Partial prepayment of Loans






	 	(a)	 	Except where this Clause 6 expressly provides otherwise, any partial prepayment of a Loan will
be applied against the Repayment Instalments in the inverse order of their maturity and shall be
applied pro rata in respect of the amounts outstanding to the Eksportfinans Lenders, the KEXIM
Lenders and the Commercial Lenders.
	 
	 	(b)	 	Upon any such partial prepayment, the Facility Agent shall, if applicable, replace the
Repayment Schedule attached at Schedule 5 (Loan Repayment Schedule) with a new Repayment
Schedule(s) reflecting the correct Repayment Instalments and promptly provide a copy thereof to the
Owner.
	 
	 	(c)	 	No amount of a Loan prepaid (in full or in part) under this Agreement may subsequently be
re-borrowed.




40









 












	6.10	 	Miscellaneous provisions






	 	(a)	 	Any notice of prepayment and/or cancellation under this Agreement is irrevocable and must
specify the relevant date(s) and the affected Loans and Commitments.
	 
	 	(b)	 	All prepayments under this Agreement must be made with accrued interest on the amount prepaid.
	 
	 	(c)	 	All prepayments (whether voluntary or mandatory) under this Agreement shall be subject to Break
Costs (if any). Each Lender claiming Break Costs shall, as soon as reasonably practicable after
demand by the Facility Agent, provide a certificate confirming the amount of its Break Costs for
any Term in which they accrue. The Facility Agent agrees to provide a copy of such certificate to
the Owner upon request by the Owner.
	 
	 	(d)	 	No prepayment or cancellation is allowed except in accordance with the express terms of this
Agreement.






	7.	 	INTEREST
	 
	7.1	 	Calculation of interest






	 	(a)	 	The rate of interest on each Commercial Loan for each Term during the Pre-Completion Period and
the Post-Completion Period is the percentage rate per annum equal to the aggregate of:






	 	(i)	 	the Applicable Margin at such time;
	 
	 	(ii)	 	LIBOR; and
	 
	 	(iii)	 	the Mandatory Cost, if any.






	 	(b)	 	The rate of interest on each Eksportfinans Loan for each Term during the Pre-Completion Period
and the Post-Completion Period shall be the aggregate of:






	 	(i)	 	the applicable Pre-Completion Eksportfinans Interest Rate or, as the case may be, the
applicable Post-Completion Eksportfinans Interest Rate; and
	 
	 	(ii)	 	the Mandatory Cost, if applicable.






	 	(c)	 	The rate of interest on each KEXIM Loan for each Term during the Pre-Completion Period and the
Post-Completion Period shall be the aggregate of:






	 	(i)	 	LIBOR; and
	 
	 	(ii)	 	the Applicable Margin at such time.






	 	(d)	 	Interest shall be calculated:






	 	(i)	 	subject to paragraph (ii) below, by reference to the actual number of days elapsed and on the
basis of a year of 360 days in respect of any Loan; and
	 
	 	(ii)	 	on a 30/360 day basis in respect of any Eksportfinans Loan.




41









 












	 	(e)	 	Interest shall accrue from and including the first day of each Term to but excluding the
last day of such Term.






	7.2	 	Payment of interest
	 
	 	 	Except where it is provided to the contrary in this Agreement, the Owner must pay accrued interest
on each Loan on the last day of each Term.
	 
	7.3	 	Interest on overdue amounts






	 	(a)	 	If the Owner fails to pay any amount payable by it under the Finance Documents, it must
immediately on demand by the Facility Agent pay interest on the overdue amount from its due date up
to the date of actual payment, both before, on and after judgment.
	 
	 	(b)	 	Interest on an overdue amount is payable at a rate determined by the Facility Agent to be the
aggregate of 3% per annum above the rate which would have been payable if the overdue amount had,
during the period of non-payment, constituted a Loan. For this purpose, the Facility Agent may
(acting reasonably) select successive Terms of any duration of up to six months.
	 
	 	(c)	 	Notwithstanding paragraph (b) above, if the overdue amount is a principal amount of a Loan and
becomes due and payable before the last day of its current Term, then:






	 	(i)	 	the first Term for that overdue amount will be the unexpired portion of that Term; and
	 
	 	(ii)	 	the rate of interest on the overdue amount for that first Term will be 3% per annum above
the rate then payable on that Loan.






	 	 	After the expiry of the first Term for that overdue amount, the rate on the overdue amount will be
calculated in accordance with paragraph (b) above.






	 	(d)	 	Interest (if unpaid) on an overdue amount will be compounded with that overdue amount at the
end of each of its Terms but will remain immediately due and payable.






	7.4	 	Notification of rates of interest
	 
	 	 	The Facility Agent must promptly notify each relevant Party of the determination of a rate of
interest under this Agreement.
	 
	8.	 	TERMS
	 
	8.1	 	Term






	 	(a)	 	Each Loan has successive Terms.
	 
	 	(b)	 	The first term for a Loan will start on the Utilisation Date for that Loan and each subsequent
Term for a Loan will start on the expiry of the preceding Term for that Loan.
	 
	 	(c)	 	Subject to the following provisions of this Clause 8 the duration of each Term shall be three
(3) months during the Pre-Completion Period, provided always that the first Term for the Incidental
Costs Loan shall expire on 31st October 2008 or if earlier, at the next Repayment Date.




42









 






	 	(d)	 	Subject to the following provisions of this Clause 8 the duration of each Term shall be
six (6) months during the Post-Completion Period, provided always that the first Term after the
Final Completion Date shall expire on the first Repayment Date set out in the Repayment Schedule,
being 30th March 2012.






	8.2	 	Consolidation — Loans
	 
	 	 	A Term for a Loan will end on the same day as the current Term for any other Loan. On the last day
of those Terms, those Loans will be consolidated and treated as one Loan.
	 
	8.3	 	End of Term on Final Completion Date
	 
	 	 	If a Term in relation to a Loan advanced during the Pre-Completion Period would otherwise overrun
the Final Completion Date, it will be shortened so that it ends on the Final Completion Date. Each
subsequent Term will be ascertained in accordance with Clause 8.1(c) (Term).
	 
	8.4	 	No overrunning the Final Maturity Date
	 
	 	 	If a Term would otherwise overrun the Final Maturity Date, it will be shortened so that it ends on
the Final Maturity Date.
	 
	8.5	 	Other adjustments
	 
	 	 	The Facility Agent (with the prior consent of the Majority Lenders) and the Owner may enter into
such other arrangements as they may agree for the adjustment of Terms and the consolidation and or
splitting of Loans.
	 
	9.	 	MARKET DISRUPTION
	 
	9.1	 	Failure of a Reference Bank to supply a rate
	 
	 	 	If LIBOR is to be calculated by reference to the Reference Banks but if a Reference Bank does not
supply a rate by 11.00 a.m. on the second London Business Day before the first day of the relevant
Term, the applicable LIBOR will, subject as provided below, be calculated on the basis of the rates
of the remaining Reference Banks.
	 
	9.2	 	Market disruption






	 	(a)	 	In this Clause 9, each of the following events is a market disruption event:






	 	(i)	 	LIBOR is to be calculated by reference to the Reference Banks but no Reference Bank supplies a
rate to the Facility Agent by 11.00 a.m. on the second London Business Day before the first day of
the relevant Term; or
	 
	 	(ii)	 	the Facility Agent receives by close of business on the second London Business Day before the
first day of the relevant term notification from any Lender or Lenders whose shares in the relevant
Loan exceed 30% of that Loan that the cost to them of obtaining matching deposits in the relevant
interbank market is in excess of LIBOR for the relevant Term.






	 	(b)	 	The Facility Agent must promptly notify the Owner and the Lenders of a market disruption event.




43









 












	 	(c)	 	After notification under paragraph (b) above, the rate of interest on each Lender’s share
in the affected Loan for the relevant Term will be the aggregate of the relevant:






	 	(i)	 	Applicable Margin at such time;
	 
	 	(ii)	 	rate notified to the Facility Agent by that Lender as soon as practicable, and in any event
before interest is due to be paid in respect of that Term, to be that which expresses as a
percentage rate per annum the cost to that Lender of funding the Loan from whatever source it may
reasonably select; and
	 
	 	(iii)	 	Mandatory Cost, if applicable, to that Lender’s participation in the Loan.






	9.3	 	Alternative basis of interest or funding






	 	(a)	 	If a market disruption event occurs and the Facility Agent or the Owner so require, the Owner
and the Facility Agent must enter into negotiations for a period of not more than 20 days with a
view to agreeing to an alternative basis for determining the rate of interest and or funding for
the affected Loan and any relevant future Loan.
	 
	 	(b)	 	Any alternative basis agreed between the Owner and the Facility Agent will be, with the prior
written consent of all the Lenders, binding on all the Parties.
	 
	 	(c)	 	During the negotiation period referred to in paragraph (a) above and thereafter unless an
agreement for such alternative basis is reached between the Parties, the provisions of Clause 9.2
shall apply.






	10.	 	TAXES
	 
	10.1	 	Tax gross-up






	 	(a)	 	The Owner must make all payments to be made by it under the Finance Documents without any Tax
Deduction unless a Tax Deduction is required by Applicable Law.
	 
	 	(b)	 	Where the introduction of, or any change in, or any change in the interpretation,
administration or application of, any Applicable Law or compliance with any law or regulation made
after the date of this Agreement requires the Owner, or as the case may be, the Facility Agent, to
make a Tax Deduction, as soon as the Owner or a Lender becomes aware of the same, it must promptly
notify the Facility Agent. The Facility Agent must then promptly notify the affected Parties.
	 
	 	(c)	 	Following any notification referred to in paragraph (b) above, the amount of the payment due
from the Owner will be increased or, as the case may be, the Owner shall make an additional
payment, so that the amount (after making the Tax Deduction) received by the recipient is equal to
the payment which would have been due if no Tax Deduction had been required.
	 
	 	(d)	 	If the Owner is required to make a Tax Deduction, it must make the Tax Deduction and must make
any payment required in connection with that Tax Deduction within the time allowed by the
Applicable Law.
	 
	 	(e)	 	Within 30 days of making either a Tax Deduction or a payment required in connection with a Tax
Deduction or, if later, promptly following receipt of the same, the Owner must deliver to the
Facility Agent for the relevant Finance Party documents or other information (or




44









 






	 	 	 	certified copies thereof) evidencing satisfactorily to that Finance Party that the Tax Deduction
has been made or (as applicable) the appropriate payment has been paid to the relevant taxing
authority.






	10.2	 	Tax indemnity






	 	(a)	 	Except as provided below, the Owner must (within three Business Days of demand by the Facility
Agent) indemnify a Finance Party by paying to such Finance Party an amount equal to any loss or
liability which that Finance Party determines will be or has been suffered by that Finance Party
for or on account of Tax in relation to a payment received or receivable (or any payment deemed to
be received or receivable) under a Finance Document.
	 
	 	(b)	 	Paragraph (a) above does not apply:






	 	(i)	 	to any Tax assessed on a Finance Party under the laws of the jurisdiction in which:






	 	(A)	 	that Finance Party is incorporated or, if different, the jurisdiction (or jurisdictions) in
which that Finance Party has a Facility Office and is treated
as resident for tax purposes; or
	 
	 	(B)	 	that Finance Party’s Facility Office is located in respect of amounts received or receivable in
that jurisdiction,






	 	 	 	if that Tax is imposed on or calculated by reference to the net income received or receivable by
that Finance Party. However, any payment deemed to be received or receivable, including any amount
treated as income but not actually received by the Finance Party, such as a Tax Deduction, will not
be treated as net income received or receivable for this purpose; or






	 	(ii)	 	to the extent a loss or liability is compensated by an increased payment under Clause 10.1(c)
(Tax gross-up).






	 	(c)	 	A Finance Party making, or intending to make, a claim under paragraph (a) above must promptly
notify the Facility Agent of the event which will give, or has given, rise to the claim. The
Facility Agent shall. in turn, notify the Owner.
	 
	 	(d)	 	A Finance Party shall, on receiving a payment from the Owner under this Clause 10.2, notify the
Facility Agent.






	10.3	 	Confidentiality of Tax affairs
	 
	 	 	If a Lender intends to make a claim pursuant to Clause 10.2 (Tax indemnity) it shall, as soon as
reasonably practicable after becoming aware that it may be entitled to make a claim under Clause
10.2 (Tax indemnity), notify the Owner of the event by reason of
which it is entitled to do so, provided that nothing herein shall require that Lender to disclose
any confidential information relating to the organisation of its affairs.
	 
	10.4	 	Stamp taxes
	 
	 	 	The Owner must pay and within five Business Days of demand indemnify each Finance Party against any
cost, loss or liability that Finance Party incurs in relation to all stamp duty, registration and
other Taxes payable in respect of any Finance Document, except for any such Tax payable in
connection with entering into a Transfer Certificate.




45









 






	10.5	 	Value added taxes






	 	(a)	 	All amounts set out, or expressed to be payable under a Finance Document by any Party to a
Finance Party which (in whole or in part) constitute the consideration for VAT purposes shall be
deemed to be exclusive of any VAT which is chargeable on such supply, and accordingly, subject to
paragraph (b) below, if VAT is chargeable on any supply made by any Finance Party to any Party
under a Finance Document, that Party must pay to the Finance Party (in addition to and at the same
time as paying the consideration) an amount equal to the amount of the VAT (and such Finance Party
must promptly provide an appropriate VAT invoice to such Party).
	 
	 	(b)	 	If VAT is chargeable on any supply made by any Finance Party (the Supplier) to any other
Finance Party (the Recipient) under a Finance Document, and any Party (the Relevant Party) is
required by the terms of any Finance Document to pay an amount equal to the consideration for such
supply to the Supplier (rather than being required to reimburse the Recipient in respect of that
consideration), such Party must also pay to the Supplier (in addition to and at the same time as
paying such amount) an amount equal to the amount of such VAT. The Recipient must promptly pay to
the Relevant Party an amount equal to any credit or repayment from the relevant tax authority which
it reasonably determines relates to the VAT chargeable on that supply.
	 
	 	(c)	 	Where a Finance Document requires any Party to reimburse a Finance Party for any costs or
expenses, that Party must also at the same time pay and indemnify the Finance Party against all VAT
incurred by the Finance Party in respect of the costs or expenses to the extent that the Finance
Party reasonably determines that neither it nor any other member of any group of which it is a
member for VAT purposes is entitled to credit or repayment from the relevant tax authority in
respect of the VAT.






	11.	 	INCREASED COSTS
	 
	11.1	 	Increased Costs
	 
	 	 	Except as provided below in this Clause 11, the Owner must, within five Business Days of demand by
the Facility Agent, pay to a Finance Party the amount of any Increased Cost incurred by that
Finance Party or any of its Affiliates as a result of:






	 	(a)	 	the introduction of, or any change in, or any change in the interpretation, administration or
application of, any Applicable Law (including, for the avoidance of doubt, the implementation of
matters set out in Basel II or any other revisions to the Basel Accord); or






	 	(b)	 	compliance with any Applicable Law made after the date of this Agreement.






	11.2	 	Exceptions
	 
	 	 	The Owner need not make any payment for an Increased Cost to the extent that the Increased Cost is:






	 	(a)	 	compensated for under another Clause or would have been but for an exception to that Clause;
	 
	 	(b)	 	attributable to the relevant Finance Party or any of its Affiliates wilfully failing to comply
with any law or regulation;




46









 






	 	(c)	 	attributable to a Tax Deduction required by Applicable Law to be made by the Owner; or
	 
	 	(d)	 	compensated for by the payment of Mandatory Cost.






	11.3	 	Claims






	 	(a)	 	If a Finance Party intends to make a claim for an Increased Cost it must notify the Facility
Agent of the circumstances giving rise to and the amount of the claim, following which the Facility
Agent will promptly notify the Owner.






	 	(b)	 	Each Finance Party must, as soon as practicable after a demand by the Facility Agent, provide a
certificate confirming the amount of its Increased Cost.






	11.4	 	Mitigation






	 	(a)	 	Each Finance Party must, in consultation with the Owner, use all reasonable endeavours to
mitigate any circumstances which arise and which result or would result in any amount being payable
under or pursuant to, or cancelled pursuant to, any of Clause 10 (Taxes) or Clause 11 (Increased
Costs) including (but not limited to) transferring its rights and obligations under the Finance
Documents to another Affiliate or Facility Office and, in respect of any Increased Cost arising as
a result of the implementation of the matters set out in Basel II or any other revisions to the
Basel Accord, each Finance Party must apply its rights under Clause 11.1(a) (Increased Costs) on a
non-discriminatory basis.






	 	(b)	 	The Owner must indemnify that Finance Party for all costs and expenses reasonably incurred by
that Finance Party as a result of any step taken by it under paragraph (a) above.






	 	(c)	 	A Finance Party is not obliged to take any step under this Clause 11.4 if, in the opinion of
that Finance Party (acting reasonably), to do so would be prejudicial to it.






	 	(d)	 	Paragraph (a) does not in any way limit the obligations of the Owner under the Finance
Documents.






	12.	 	ACCOUNTS






	12.1	 	Maintenance of accounts






	 	(a)	 	The Owner shall maintain the Accounts (other than the Equity Account) with the Account Bank
until the Final Maturity Date, in each case free of Security Interests and rights of set- off other
than as created by or pursuant to the Security Documents or in favour of the Account Bank.






	 	(b)	 	The Owner shall maintain the Equity Account with the Equity Account Bank until the Final
Completion Date, in each case free of Security Interests and rights of set-off other than as
created by or pursuant to the Security Documents.






	12.2	 	Proceeds Account and Equity Account






	 	(a)	 	The Owner shall pay, or procure that there is paid:






	 	(i)	 	no later than one (1) Business Day after the date of service of each Request to the Facility
Agent in the Pre-Completion Period, into the Proceeds Account, an amount equal to:






47











 






	 	(A)	 	any Balancing Equity Contribution; and
	 
	 	(B)	 	the relevant Equity Contribution, in each case in respect of the Utilisation Date to which such
Request relates; and






	 	(ii)	 	the amount of each Loan into the Proceeds Account or if the Owner so requests in a Request in
respect of an Instalment Loan, to an account of the Builder specified in the Request; and
	 
	 	(iii)	 	into the Equity Account:






	 	(A)	 	no later than one (1) Business Day after the date of service of the Request in respect of the
Incidental Costs Loan, an aggregate amount equal to US$9,000,000;
	 
	 	(B)	 	no later than one (1) Business Day after the date of service of the Request in respect of
Instalment Loan 1, an aggregate amount equal to US$90,000,000; and
	 
	 	(C)	 	on or prior to the Amendment and Restatement Effective Date, an aggregate amount equal to all anticipated
Equity Contributions to be made until the Final Completion Date in accordance with the relevant
Approved Budget.






	 	(b)	 	If an Event of Default occurs, the Owner shall pay, or procure that there is paid, into the
Equity Account an aggregate amount equal to all of the Equity Collateral that has not yet been
paid.
	 
	 	(c)	 	Subject to the Owner’s right to make withdrawals from the Equity Account in accordance with the
provisions of this Agreement, the Owner shall ensure that the balance in the Equity Account at all
times meet the requirements set out in this Clause 12.2.
	 
	 	(d)	 	If on the Amendment and Restatement Effective Date no Event of Default or Mandatory
Prepayment Event has occurred and is continuing, the funds standing to the credit of the
Equity Account (other than the anticipated Equity Contributions paid into the Equity
Account in accordance with Clause 12.2 (a) (iii) (C)) shall be released to the Owner or to its
order.
	 
	 	(e)	 	During the Pre-Completion Period and on the Final Completion Date the Owner shall procure that
there is forthwith credited to the Proceeds Account any other amount payable or paid to the Owner
(including any Liquidated Damages Payments paid by the Builder under the terms of the Shipbuilding
Contract). Provided that no Event of Default or Mandatory Prepayment Event has occurred and is
continuing, the Owner shall be entitled to instruct the Account Bank or, as the case may be, the
Equity Account Bank to transfer (and irrevocably authorises the Security Trustee to instruct the
Account Bank or, as the case may be, the Equity Account Bank to transfer):






	 	(i)	 	on or immediately before each Utilisation Date, from the Equity Account into the Proceeds
Account, an amount equal to the relevant Equity Contribution in respect of such Utilisation Date;
and
	 
	 	(ii)	 	on each Utilisation Date, after the proceeds of the relevant Loan have been credited,
sufficient amounts from the Proceeds Account to (A) any account specified by the Builder to be
applied to make Instalment payments or, in the case that the relevant




48









 












	 	 	 	Loan is to be used to refinance the Instalment payment
already paid to the Builder by the Owner, any account specified by
the Owner, and (B) the account nominated by the Facility Agent, to be
applied to part of the Incidental Costs Loan as does not relate to Incidental Vessel Costs, and (C) any account specified by the Owner to be applied towards such
other items or costs as are included in the Vessel Cost.






	 	 	in each case in accordance with the terms
of this Agreement.






	 	(f)	 	During the Post-Completion Period, the Owner shall procure that there is forthwith credited to
the Proceeds Account all Earnings and any Requisition Compensation. The Owner shall procure that
the following transfers will then be made in the following order:






	 	(i)	 	first, to the Operating Expenses Account a transfer in accordance with Clause 12.3 (Transfers
to the Operating Expenses Account);
	 
	 	(ii)	 	secondly, to the Debt Service Account a transfer in accordance with Clause 12.4 (Transfers to
Debt Service Account);
	 
	 	(iii)	 	thirdly, to the extent required, a transfer to the Debt Service Reserve Account in accordance
with Clause 12.9(b) (Payments to the Debt Service Reserve Account on or after the Utilisation Date
of the Delivery Loan); and
	 
	 	(iv)	 	fourthly, to the extent required, a transfer to the CAPEX Account in accordance with Clause
12.10 (Transfers to the CAPEX Account),








	 	 	 	together the Primary Transfers.
	 
	 	(g)	 	Once the Primary Transfers have been made, any surplus funds standing to the credit of the
Proceeds Account (if at least US$5,000,000) shall be applied by the Security Trustee in partial
prepayment of the Loans and Clauses 6.9 and 6.10 shall apply.
	 
	 	(h)	 	Provided no Default or Mandatory Prepayment Event is at such time continuing, the Owner and the
Finance Parties may, notwithstanding the provisions of this Clause 12 vary the order and
application of the Primary Transfers by agreement in writing, in each case acting reasonably.






	12.3	 	Transfers to the Operating Expenses Account
	 
	 	 	Upon payment of any Earnings or Requisition Compensation into the Proceeds Account (such date of
receipt of payment being an Earnings Deposit Date) the Owner shall instruct the Account Bank to
transfer from the Proceeds Account (and irrevocably authorises the Security Trustee to instruct the
Account Bank to transfer from the Proceeds Account) to the Operating Expenses Account an amount
equal to the amount allocated for Operating Expenses in the Annual Budget for the period from that
Earnings Deposit Date to the next scheduled Earnings Deposit Date, and the Owner shall be permitted
to withdraw such amount from the Operating Expenses Account to pay the same to the Manager under
and in accordance with the terms of the Management Agreement and to others for use in connection
with the operating expenses of the Vessel and operation and management of the Owner incurred in the
ordinary course of business.
	 
	12.4	 	Transfers to Debt Service Account
	 
	 	 	Following the transfer to the Operating Expenses Account in accordance with Clause 12.3 (Transfers
to the Operating Expenses Account), the Owner shall procure that there is transferred from the





49









 











	 	 	Proceeds Account (and irrevocably instructs the Security Trustee to instruct the Account Bank to
transfer from the Proceeds Account) to the Debt Service Account an amount in Dollars calculated in
accordance with the following formula:





	 	 	 	 	 	 

	 	a =

	 	A x n
 

N
	 	 







	 	 	 	 	 	 

	 	where:

	 	
	 	
	 
	 	a

	 	=
	 	the relevant amount of the Earnings and/or, as the case may be, Requisition Compensation to be
transferred to the
Debt Service Account out of the Proceeds Account;
	 	 
	 	 	 	 
	 	A

	 	=
	 	the aggregate amount required to repay the next scheduled principal and interest instalment
(provided that for the
purposes of this Clause 12.4, scheduled interest in respect of any Hedged Portion shall be deemed
to be payable at
the applicable Fixed Rate);
	 	 
	 	 	 	 
	 	N

	 	=
	 	the number of days in a Retention Period; and
	 	 
	 	 	 	 
	 	n

	 	=
	 	the actual number of days elapsed from (and including) the immediately preceding Earnings
Deposit Date in the
Retention Period or the first day of the Retention Period (where there is no preceding Earnings
Deposit Date in a
Retention Period) up to (but excluding) the Earnings Deposit Date,







	 	 	PROVIDED ALWAYS that on the last Earnings Deposit Date for a Retention Period if there remains a
shortfall under the formula set out in this Clause 12.4 on the last day of a Retention Period,
there shall be transferred to the Debt Service Account out of the Proceeds Account an amount
(taking into account the existing balance of the Debt Service Account) equal to the amount required
to repay the principal and interest in full which is due on the next Repayment Date.
	 
	12.5	 	Additional payments to the Debt Service Accounts
	 
	 	 	If, for any reason, the amount standing to the credit of the Proceeds Account is insufficient to
make any transfer to the Debt Service Account required by
Clause 12.4 (Transfers to Debt Service Account), the Owner shall immediately (and in any event
within three Business Days of the relevant Earnings Deposit
Date) pay the shortfall directly into the Debt Service Account.
	 
	12.6	 	Application of Debt Service Accounts






	 	(a)	 	On each Repayment Date:






	 	(i)	 	to the extent that the Owner is required to make a periodic payment to a Swap Bank under a Swap
Agreement, the Owner shall procure that (and irrevocably authorises the Security Trustee to
instruct the Account Bank to transfer from the Debt Service Account) an amount equal to the
aggregate of any such periodic payments is transferred forthwith from the Debt Service Account to
the relevant Swap Bank in accordance with the DPP; and
	 
	 	(ii)	 	to the extent that a Swap Bank is required to make a periodic payment to the Owner under a
Swap Agreement then the Owner shall request that the Swap Bank pays such periodic payment directly
into the Debt Service Account when due.




50









 












	 	(b)	 	The Owner shall procure that there is transferred from the Debt Service Account (and
irrevocably authorises the Security Trustee to instruct the Account Bank to transfer from the Debt
Service Account) to the Facility Agent after any payment to a Swap Bank as described in paragraph
(a)(i) above:






	 	(i)	 	on each Repayment Date, the amount of the Repayment Instalment then due in Dollars; and
	 
	 	(ii)	 	on the last day of each Term, the amount of interest then due in Dollars,






	 	 	provided that following the transfer to the Facility Agent in accordance with this Clause 12.6(b),
the Owner shall be entitled to request the Security Trustee to authorise the transfer of any
remaining funds standing to the credit of the Debt Service Account back to the Proceeds Account.
	 
	12.7	 	Owner’s obligations not affected
	 
	 	 	If for any reason the amount standing to the credit of the Debt Service Account shall be
insufficient to pay any Repayment Instalment or to make any payment of interest when due, the
Owner’s obligation to pay that Repayment Instalment or to make that payment of interest shall not
be affected.
	 
	12.8	 	Payments to the Debt Service Reserve Account prior to the Utilisation Date of the Delivery
Loan






	 	(a)	 	The Owner shall pay, or procure that there is paid to the Debt Service Reserve Account on or
prior to the Amendment and Restatement Effective Date an amount equal to US$25,000,000.
	 
	 	(b)	 	At any time, and from time to time, prior to the Final Completion Date, the Owner shall be
entitled, with the prior approval of the Facility Agent (acting on the instructions of the Majority
Lenders), to withdraw all or part of the moneys standing to the credit of the Debt Service Reserve
Account in order to meet any costs and expenses the Owner may incur which have not been
contemplated in the Approved Budget.
	 
	 	(c)	 	Any balance standing to the credit of the Debt Service Reserve Account on the Utilisation Date
of the Delivery Loan, shall be utilised towards the funding of the Required DSRA Balance.






	12.9	 	Payments to the Debt Service Reserve Account on or after the Utilisation Date of the Delivery
Loan






	 	(a)	 	The Owner shall ensure, from the Utilisation Date of the Delivery Loan and at all times
thereafter until the Final Maturity Date, that the amount standing to the credit of the Debt
Service Reserve Account is equal to the Required DSRA Balance.
	 
	 	(b)	 	On each Earnings Deposit Date, following the transfers referred to in Clauses 12.3 and 12.4
above, the Owner shall procure that there is transferred from the Proceeds Account (and irrevocably
authorises the Security Trustee to instruct the Account Bank to transfer from the Proceeds Account)
to the Debt Service Reserve Account an amount to ensure that the balance of the Debt Service
Reserve Account at such time is an amount at least equal to the Required DSRA Balance.




51









 












	 	(c)	 	The Security Trustee shall be entitled to withdraw sums of money standing to the credit of
the Debt Service Reserve Account in accordance with the terms of the Accounts Charge Agreement.






	12.10	 	Transfers to the CAPEX Account
	 
	 	 	On each Earnings Deposit Date, following the transfers referred to above (to the extent any such
payments are required to be made under and in accordance with the terms thereof), the Owner shall
instruct the Account Bank to transfer from the Proceeds Account (and irrevocably authorise the
Security Trustee to instruct the Account Bank to transfer from Proceeds Account) to the CAPEX
Account an amount equal to the amount allocated for CAPEX Expenses, if any, in the Annual Budget
for the period from that Earnings Deposit Date to the next scheduled Earnings Deposit Date, and the
Owner shall be entitled, in accordance with the terms of the Annual Budget, with the prior consent
of the Security Trustee, to withdraw such amount from the CAPEX Account to pay (against
reasonable and proper invoices approved by the Facility Agent) any approved CAPEX Expenses.
	 
	12.11	 	Investments
	 
	 	 	The Facility Agent may invest any and all moneys held in the Debt Service Reserve Account in the
name of, or under the control of, the Facility Agent in short term cash deposits at the Deposit
Bank and upon such terms as the Facility Agent may think fit. If the rating of the Deposit Bank
falls below P-1 from Moody’s or A-1 from S&P, the Facility Agent must promptly remove the deposits
placed under this Clause 12.11 from the Deposit Bank and invest the relevant deposits at any bank
or institution with a rating of not less than P-1 from Moody’s
or A-1 from S&P, selected by the
Facility Agent and approved by the Owner and the Majority Lenders. Notwithstanding any investment
in accordance with this Clause 12.11, all moneys paid into the Debt Service Reserve Account shall
at all times be charged to the benefit of the Secured Parties.
	 
	12.12	 	Restriction on withdrawal
	 
	 	 	During the term of the Facility, no sum may be withdrawn from any of the Accounts (except in
accordance with this Clause 12) without the prior written consent of the Facility Agent (acting on
the instructions of the Majority Lenders).
	 
	12.13	 	Liability of Account Bank
	 
	 	 	Each Lender agrees to the terms of the appointment of the Account Bank and confirms that the
Account Bank has no liability to the Lenders in respect of amounts withdrawn from any Account (in
accordance with this Agreement and the Accounts Charge Agreement). Notwithstanding the provisions
of Clause 1.2(c) (Construction), the Account Bank may enforce the terms of this Clause 12.13 as if
it were a party to this Agreement.
	 
	13.	 	PAYMENTS
	 
	13.1	 	Place
	 
	 	 	Unless a Finance Document specifies that payments under it are to be made in another manner, all
payments by a Party (other than the Facility Agent) under the Finance Documents must be made to the
Facility Agent to its account at such office as it may notify’ to that Party for this purpose by
not less than five Business Days’ prior notice.




52









 












	13.2	 	Funds
	 
	 	 	Payments under the Finance Documents to the Facility Agent must be made for value on the due date
at such times and in such funds as the Facility Agent
may specify to the Party concerned as being customary at the time for the settlement of
transactions in the relevant currency in the place for payment.
	 
	13.3	 	Distribution






	 	(a)	 	Each payment received by the Facility Agent under the Finance Documents for another Party must,
except as provided below, be made available by the Facility Agent to that Party by payment (as soon
as practicable after receipt) to its account with such office or, in the case of KEXIM, in New York
as it may notify to the Facility Agent for this purpose by not less than five Business Days’ prior
notice.
	 
	 	(b)	 	The Facility Agent may apply any amount received by it from the Owner in or towards payment (as
soon as practicable after receipt) of any amount due from the Owner under the Finance Documents or
in or towards the purchase of any amount of any currency to be so applied.
	 
	 	(c)	 	Where a sum is paid to the Facility Agent under this Agreement for another Party, the Facility
Agent is not obliged to pay that sum to that Party until it has established that it has actually
received it. However, the Facility Agent may assume that the sum has been paid to it, and, in
reliance on that assumption, make available to that Party a corresponding amount. If it transpires
that the sum has not been received by the Facility Agent, that Party must forthwith on demand by
the Facility Agent refund any corresponding amount made available to it together with interest on
that amount from the date of payment to the date of receipt by the Facility Agent at a rate
reasonably calculated by the Facility Agent to reflect its cost of funds.






	13.4	 	Currency






	 	(a)	 	Unless a Finance Document specifies that payments under it are to be made in a different
manner, the currency of each amount payable under the Finance Documents is determined under this
Subclause.
	 
	 	(b)	 	Amounts payable in respect of Taxes, fees, costs and expenses are payable in the currency in
which they are incurred.
	 
	 	(c)	 	Each other amount payable under the Finance Documents is payable in Dollars.






	13.5	 	No set-off or counterclaim
	 
	 	 	All payments made by the Owner under the Finance Documents must be calculated and made without (and
clear of any deduction for) set-off or counterclaim.
	 
	13.6	 	Business Days






	 	(a)	 	If a payment under the Finance Documents is due on a day which is not a Business Day, the due
date for that payment will instead be the next Business Day in the same month (if there is one) or
the preceding Business Day (if there is not).




53









 












	 	(b)	 	During any extension of the due date for payment of any principal under this Agreement interest
is payable on that principal at the rate payable on the original due date.






	13.7	 	Payments






	 	(a)	 	Subject always to the provisions of the DPP and except to the extent otherwise provided in any
Finance Document, if any Administrative Party receives a payment insufficient to discharge all the
amounts then due and payable by the Owner under the Finance Documents, then the Administrative
Party must apply that payment towards the obligations of the Owner under the Finance Documents in
the following order:






	 	(i)	 	first, in or towards payment or satisfaction pro rata of all costs, charges, sales taxes,
expenses and liabilities incurred and due and payments made by the Finance Parties, the Account
Bank or any receiver in enforcing rights under the Finance Documents and/or recovering possession
of the Security Assets and all remuneration payable to the Finance Parties for which the relevant
Finance Party is entitled to be reimbursed under the Finance Documents or any receiver under or
pursuant to the Security Documents (including, without limitation, legal expenses and reinstatement
costs) provided that, in respect of any such payment or payments payable to the Swap Banks, the
amount paid shall not exceed the Swap Limit;
	 
	 	(ii)	 	secondly, in or towards payment pro rata of any due and unpaid fees, costs and expenses
of the Finance Parties or the Account Bank under the Finance Documents to the extent not recovered
under subparagraph (i) above provided that, in respect of any such payment or payments payable to
the Swap Banks the amount paid, when aggregated with any amounts recovered by the Swap Banks under
subparagraph (i) above, shall not exceed the Swap Limit;
	 
	 	(iii)	 	thirdly, in or towards payment pro rata of any interest on overdue amounts payable to the
Finance Parties provided that, in respect of any such payment or payments payable to the Swap Banks
the amount paid, when aggregated with any amounts recovered by the Swap Banks under subparagraphs
(i) and (ii) above, shall not exceed the Swap Limit;
	 
	 	(iv)	 	fourthly, in or towards payment pro rata of any accrued but due and unpaid interest (other
than interest on overdue amounts referred to in subclause (iii)) payable to the Finance Parties
provided that, in respect of any such payment or payments payable to the Swap Banks the amount
paid, when aggregated with any amount recovered by the Swap Banks under subparagraphs (i), (ii) and
(iii) above, shall not exceed the Swap Limit;
	 
	 	(v)	 	fifthly, in or towards payment pro rata of:






	 	(A)	 	any due but unpaid Break Costs of the Finance Parties; or
	 
	 	(B)	 	any due but unpaid principal payable to the Finance Parties,






	 	 	 	in each case, under the Finance Documents provided that, in
respect of any such payment or payments
payable to the Swap Banks the amount paid, when aggregated with any amount recovered by the Swap
Banks under subparagraphs (i), (ii), (iii) and (iv) above, shall not exceed the Swap Limit;





54









 











	 	(vi)	 	sixthly, in or towards payment pro rata to the Finance Parties of any other amounts which are
due but unpaid by the Owner to any of the Finance Parties under the Finance Documents in such order
as the Finance Parties shall determine provided that, in respect of any such payment or payments
payable to the Swap Banks the amount paid, when aggregated with any amount recovered by the Swap
Banks under subparagraphs (i), (ii), (iii), (iv) and (v) above, shall not exceed the Swap Limit;
	 
	 	(vii)	 	seventhly, any payments due but unpaid to the Swap Banks under a Swap Agreement to the extent
not already recovered under paragraphs (i), (ii), (iii), (iv), (v) and (vi) above; and
	 
	 	(viii)	 	after all amounts payable or which may become payable to the Finance Parties under the
Finance Documents have been paid in full, in or towards payment of the surplus, if any, to the
Owner or other persons entitled thereto free of any charge or other restriction.






	 	(b)	 	The Facility Agent must, if so directed by all the Lenders, vary the order set at subparagraphs
(a)(ii) to (a)(vi) above, provided always that to the extent that the provisions of this paragraph
shall conflict with the DPP, the provisions of the DPP shall prevail. Any amendment or variation to
any other provision of this Agreement other than the order of payments in paragraph (a) above shall
require the prior written consent of the Owner.
	 
	 	(c)	 	This Clause 13.7 will override any appropriation made by the Owner.






	13.8	 	Timing of payments
	 
	 	 	If a Finance Document does not provide for when a particular payment is due, including any
indemnity payment, that payment will be due within three Business Days of demand by the relevant
Finance Party.
	 
	14.	 	REPRESENTATIONS AND WARRANTIES
	 
	14.1	 	Representations and warranties
	 
	 	 	The representations and warranties set out in this Clause 14 are made, unless otherwise stated, by
the Owner to the Finance Parties.
	 
	14.2	 	Status and Ownership






	 	(a)	 	It is a corporation, duly organised and validly existing under the laws of the Marshall
Islands.
	 
	 	(b)	 	It has the power to own its assets and carry on its business as it is being conducted.
	 
	 	(c)	 	It is indirectly wholly owned by Ocean Rig (acting through the Parent and the Parent
Shareholder) and indirectly majority owned by the Sponsor (acting through Ocean Rig, the
Parent and the Parent Shareholder).
	 
	 	(d)	 	Subject to the Security Documents, the Parent is the legal and beneficial owner of all of the
share capital of the Owner, the Parent Shareholder is the legal and beneficial owner of all of
the share capital of the Parent, Ocean Rig is the legal and beneficial owner of all of the share
capital of the Parent Shareholder and the Sponsor is the legal and beneficial owner of the
majority of the share capital of Ocean Rig.




55









 












	 	(e)	 	No person has any right to call for the issue or transfer of any share capital or loan stock in
the Owner other than in accordance with the Security Documents.
	 
	 	(f)	 	All of the shares in the capital of the Owner are fully paid up.






	14.3	 	Powers and authority
	 
	 	 	It has the power to enter into and perform, and has taken all necessary action to authorise the
entry into and performance of, the Transaction Documents to which it is or will be a party and the
transactions contemplated by those Transaction Documents.
	 
	14.4	 	Legal validity






	 	(a)	 	Subject to any general principles of law limiting its obligations, each Transaction Document to
which it is a party is its legally binding, valid and enforceable obligation.
	 
	 	(b)	 	This Agreement and each Transaction Document to which it is a party is in the proper form for
its enforcement in the jurisdiction of its incorporation.






	14.5	 	Non-conflict
	 
	 	 	The entry into and performance by it of, and the transactions contemplated by, the Transaction
Documents to which it is a party do not conflict in any material respect with:






	 	(a)	 	any law or regulation applicable to it;
	 
	 	(b)	 	its constitutional documents; or
	 
	 	(c)	 	any agreement or instrument which is binding upon it or any of its assets.






	14.6	 	No Default






	 	(a)	 	No Default is outstanding under, or will result from the entry into, or the performance by it
of any transaction contemplated by, any Transaction Document.
	 
	 	(b)	 	There is no outstanding material breach of any term of any Transaction Document to which it is
a party and no person has disputed, repudiated or disclaimed liability under any Transaction
Document to which it is a party or evidenced an intention to do so.
	 
	 	(c)	 	No other event is outstanding which constitutes a default under any document which is binding
on it or any of its assets to an extent or in a manner which is reasonably likely to have a
Material Adverse Effect.






	14.7	 	Authorisations






	 	(a)	 	Under Marshall Islands law and the laws of any other jurisdiction where the Owner carries on
business, except for the registration of the Mortgage at the Marshall Islands Ships Registry, all
authorisations required by it in connection with the entry into, performance, validity and
enforceability of, and the transactions contemplated by, the Finance Documents have been obtained
or effected (as appropriate) and are in full force and effect or will be in full force and effect
at the time such authorisations are required in such jurisdiction.




56









 












	 	(b)	 	It is not aware of:






	 	(i)	 	any reason why any Transaction Authorisation required by it will not be obtained or effected by
the time it is required;
	 
	 	(ii)	 	any steps to revoke or cancel any Transaction Authorisation required by it; or
	 
	 	(iii)	 	any reason why any Transaction Authorisation required by it will not be renewed when it
expires without the imposition of any new restriction or condition.






	14.8	 	Financial statements
	 
	 	 	Its audited financial statements (if any) most recently delivered to the Facility Agent together
with any other financial information supplied by it to the Facility
Agent:






	 	(a)	 	have been prepared in accordance with IFRS or US GAAP, as the case may be, consistently
applied; and
	 
	 	(b)	 	give a true and fair view of its financial condition as at the date to which they were drawn
up,






	 	 	except, in each case, as disclosed to the contrary in those financial statements.
	 
	14.9	 	Financial and other information
	 
	 	 	In addition, and without prejudice to, the representations made under Clause 14.8 (Financial
statements), any financial and other information disclosed is accurate and complete in all material
respects and does not contain any untrue statement of a material fact or omit to state a material
fact necessary to make the statements therein, in the light of the circumstances in which they are
made, not misleading.
	 
	14.10	 	No material adverse change
	 
	 	 	There has been no material adverse change in the assets, business, condition (financial or
otherwise) or operations of the Owner since its incorporation or,
following the receipt by the Facility Agent of its audited annual financial statements, since the
date of its then latest audited annual financial statements.
	 
	14.11	 	Litigation
	 
	 	 	Except as may already have been disclosed by the Owner in writing to the Facility Agent, no
litigation, arbitration or administrative proceedings of or before any court, arbitral body or
agency (including, but not limited to, investigative proceedings) have been started and are current
or (to the best of its knowledge and belief) threatened in writing against the Owner which, in each
case, in the reasonable opinion of the Facility Agent acting on the instructions of the Majority
Lenders, would be likely to have a Material Adverse Effect in respect of the Owner.
	 
	14.12	 	Pari passu ranking
	 
	 	 	Its payment obligations under the Finance Documents rank at
least pari passu with all its other
present and future unsecured payment obligations, except for obligations mandatorily preferred by
law applying to companies generally.




57









 












	14.13	 	Taxes on payments






	 	(a)	 	It is not required under the law of its jurisdiction of incorporation to make any Tax Deduction
for or on account of Tax from any payment it may make under a Finance Document.
	 
	 	(b)	 	No claims are being, nor, as far as it is aware, might reasonably be expected to be, asserted
against it with respect to Taxes.






	14.14	 	Stamp and registration duties
	 
	 	 	As at the date of this Agreement, no stamp or registration duty or similar Tax or charge is payable
in its jurisdiction of incorporation in respect of any Transaction Document.
	 
	14.15	 	Environment






	 	(a)	 	The Owner and, to the best of the Owner’s knowledge and belief (having made due enquiry), its
Environmental Affiliates are in compliance with all material provisions of all applicable
Environmental Laws in relation to the Vessel and its operations;
	 
	 	(b)	 	The Owner and, to the best of the Owner’s knowledge and belief (having made due enquiry), its
Environmental Affiliates have obtained or will, by the Delivery Date, have obtained all requisite
Environmental Approvals in relation to the Vessel and its operations are and will, on the Delivery
Date and at all times thereafter be in compliance, with such Environmental Approvals;
	 
	 	(c)	 	Neither the Owner nor, to the best of the Owner’s knowledge and belief (having made due
enquiry), any of its Environmental Affiliates has received notice of nor have issued (or threatened
to issue) any Environmental Claim in excess of US$2,500,000 or which, when aggregated with any
other Environmental Claim in relation to the Vessel or its operations in any 12-month period,
exceeds US$10,000,000 in relation to the Vessel which alleges that the Owner is not in compliance
with applicable Environmental Laws in relation to the Vessel or Environmental Approvals in relation
to the Vessel;
	 
	 	(d)	 	There is no Environmental Claim in relation to the Vessel in excess of US$2,500,000 or which,
when aggregated with any other Environmental Claim in relation to the Vessel and its operations,
exceeds US$10,000,000 pending or, to the best of its knowledge and belief, threatened in writing;
	 
	 	(e)	 	There has been no Release of Hazardous Materials by or in respect of the Vessel which could
lead to an Environmental Claim in relation to the Vessel or its operations in excess of
US$2,500,000 or which, when aggregated with any other Environmental Claim in relation to the Vessel
or its operations, exceeds US$10,000,000; and
	 
	 	(f)	 	to the best of the Owner’s knowledge and belief (having made due inquiry), the Charterer has
obtained and is in compliance with all Environmental Approvals required of a Charterer in
connection with use of the Vessel, and the Charterer is in compliance in all material respects with
all Environmental Laws to the extent relating to the offshore lease blocks in which the Vessel will
operate pursuant to a Drilling Charter.





58









 











	14.16	 	Security Interests
	 
	 	 	No Security Interest exists over its assets which would cause a breach of Clause 16.6 (Security
Interests).
	 
	14.17	 	Security Assets






	 	(a)	 	Subject to Permitted Liens and any rights of the Charterer under a Drilling Charter, the Owner
is the sole legal and beneficial owner entitled to the Security Assets over which it has or will
create any Security Interest pursuant to the Security Documents to which it is or will be a party
and there is no agreement or arrangement, other than in the DPP, under which it is obliged to share
any proceeds of or derived from such Security Assets with any third party.
	 
	 	(b)	 	Each Security Document to which it is or will be a party creates or will create first priority
security interests of the type described.






	14.18	 	ISM Code compliance
	 
	 	 	On the Delivery Date the Owner and the Manager is in compliance in all material respects with all
of the mandatory requirements of the ISM Code in respect of the Vessel.
	 
	14.19	 	ISPS Code compliance
	 
	 	 	On the Delivery Date the Owner and the Manager is in compliance in all material respects with all
of the mandatory requirements of the ISPS Code in respect of the Vessel.
	 
	14.20	 	No amendments to Related Contracts
	 
	 	 	Other than as notified to and agreed by the Facility Agent in writing, there have been no
amendments to any of the Related Contracts (other than any amendments of a non-material or
administrative nature or a replacement of the Manager in accordance with the provisions of this
Agreement).
	 
	14.21	 	Money laundering
	 
	 	 	Any borrowing by the Owner and the performance of its obligations hereunder and under the other
Finance Documents to which it is a party will be for its own account and will not involve any
breach by it of any law or regulatory measure relating to money
laundering as defined in Article 1
of the Directive (91/308/EEC) of the Council of the European Communities or any equivalent law or
regulatory measure in any other jurisdiction.
	 
	14.22	 	Insolvency






	 	(a)	 	The Owner is not unable or deemed unable, does not admit and has not admitted its inability to
pay its debts and has not suspended making payments on any of its debts.
	 
	 	(b)	 	The Owner by reason of actual or anticipated financial difficulties has not commenced, and does
not intend to commence, negotiations with one or more of its creditors with a view to rescheduling
any of its Financial Indebtedness.
	 
	 	(c)	 	The value of the assets of the Owner is not less than its liabilities (taking into account
contingent and prospective liabilities).




59









 












	 	(d)	 	No moratorium has been declared in respect of any indebtedness of the Owner during the period
of six months commencing on the date this representation is made or deemed to be repeated pursuant
to Clause 14.30(a) (Times for making representations).






	14.23	 	Immunity






	 	(a)	 	The entry into by it of each Transaction Document to which it is a party constitutes, and the
exercise by it of its rights and performance of its obligations under each such Transaction
Document will constitute, private and commercial acts performed for private and commercial
purposes.
	 
	 	(b)	 	It will not be entitled to claim immunity from suit, execution, attachment or other legal
process in any proceedings taken in its jurisdiction of incorporation in relation to any
Transaction Document.






	14.24	 	No adverse consequences






	 	(a)	 	It is not necessary under the laws of its jurisdiction of incorporation:






	 	(i)	 	in order to enable a Finance Party to enforce its rights under any Finance Document; or
	 
	 	(ii)	 	by reason of the entry into of any Finance Document or the performance by it of its
obligations under any Finance Document,






	 	 	 	that any Finance Party should be licensed, qualified or otherwise entitled to carry on business in
its jurisdiction of incorporation.
	 
	 	(b)	 	No Finance Party will be deemed to be resident, domiciled or carrying on business in its
jurisdiction of incorporation by reason only of the entry into, performance and/or enforcement of
any Finance Document.






	14.25	 	Jurisdiction/governing law






	 	(a)	 	Its:






	 	(i)	 	irrevocable submission under this Agreement to the jurisdiction of the courts of England;
	 
	 	(ii)	 	agreement that this Agreement is governed by English law; and
	 
	 	(iii)	 	agreement not to claim any immunity to which it or its assets may be entitled,






	 	 	 	are legal, valid and binding under the laws of its jurisdiction of incorporation.
	 
	 	(b)	 	Any judgment obtained in England will be recognised and be enforceable by the courts of its
jurisdiction of incorporation, subject to any statutory or other conditions of such jurisdiction.






	14.26	 	Anti-bribery
	 
	 	 	Neither the Owner, nor anyone acting on its behalf, have been engaged or will engage in bribery in
this transaction. Neither the Owner or anyone acting on his behalf in connection with the
transaction are currently under charge in a national court or, within a five-year period preceding
the date of this Agreement, have been convicted in a national court or been subject to equivalent
national




60









 












	 	 	administrative measures for violation of laws against bribery of foreign public officials
of any country or are listed on the publicly available debarment lists of the following
international financial institutions: World Bank Group, African Development Bank, Asian Development
Bank, European Bank for Reconstruction and Development and the Inter-American Development Bank.
	 
	14.27	 	No other business






	 	(a)	 	Except as expressly contemplated by the Transaction Documents, it has not traded or carried on
any business since the date of its incorporation.
	 
	 	(b)	 	It does not have any Subsidiaries.
	 
	 	(c)	 	It is not a party to any agreement other than the Transaction Documents.






	14.28	 	Shipbuilding Contract
	 
	 	 	There has been no amendment to or variations made or agreed with the Builder in respect of the
Shipbuilding Contract or the Other Shipbuilding Contract from the date of the Shipbuilding Contract
or, as the case may be, the Other Shipbuilding Contract save for those already disclosed in writing
to the Facility Agent prior to the date hereof or approved in writing by the Facility Agent (acting
on the instructions of the Majority Lenders).
	 
	14.29	 	Activities in the Marshall Islands






	 	(a)	 	Neither the Owner, the Parent, the Parent Shareholder, Ocean Rig nor the Sponsor or any of their
respective parents, subsidiaries or affiliates is a division, bureau, office, agency, department,
committee or political subdivision of the jurisdiction of its incorporation or any other sovereign
jurisdiction.
	 
	 	(b)	 	Neither the Owner, the Parent, the Parent Shareholder, Ocean Rig nor the Sponsor is engaged in:






	 	(i)	 	the retailing, wholesaling, trading or importing of goods or services for or with residents of
the jurisdiction of its incorporation;
	 
	 	(ii)	 	any extractive industry in the jurisdiction of its incorporation;
	 
	 	(iii)	 	any regulated professional service activity in the jurisdiction of its incorporation;
	 
	 	(iv)	 	the export of any commodity or goods manufactured, processed, mined or made in the
jurisdiction of its incorporation; or
	 
	 	(v)	 	the ownership of real property in its jurisdiction of incorporation.






	 	(c)	 	Neither the Owner, the Parent, the Parent Shareholder, Ocean Rig nor the Sponsor is doing business in the
jurisdiction of its incorporation, except that each of the Owner, the Parent, the Parent
Shareholder or the Sponsor may have its registered office in the jurisdiction of its incorporation
and maintain its agent there.






	14.30	 	Times for making representations and warranties






	 	(a)	 	The representations and warranties set out in this Clause 14 are made by the Owner on the date
of this Agreement and shall be deemed to be repeated on each Utilisation Date and each date during
the Post-Completion Period.




61









 












	 	(b)	 	When a representation and warranty is repeated, it is applied to the circumstances existing at
the time of repetition.






	14.31	 	Legal qualifications
	 
	 	 	The representations and warranties set out in Clauses 14.4 (Legal validity), 14.5(a)
(Non-conflict), 14.12 (Pari passu ranking) and 14.25 (Jurisdiction/governing law) are made by
reference to any qualifications, reservations, limitations or exceptions as to matters of law set
out in the relevant legal opinions required under this Agreement.
	 
	15.	 	INFORMATION COVENANTS
	 
	15.1	 	Financial statements






	 	(a)	 	The Owner must supply to the Facility Agent, in electronic form by email attachment or hard
copy (and, if in hard copy, in sufficient copies for all of the Lenders), its audited financial
statements for each of its financial years ending after the date of this Agreement.
	 
	 	(b)	 	The Owner shall procure that each of the Sponsor and Ocean Rig shall supply to the Facility Agent its audited
consolidated financial statements for each of its financial years ending after the date of this
Agreement.
	 
	 	(c)	 	The Owner must supply to the Facility Agent, in electronic form by email attachment or hard
copy (and, if in hard copy, in sufficient copies for all of the Lenders), its interim unaudited
financial statements for each quarter of each financial year ending after the date of this
Agreement.
	 
	 	(d)	 	The Owner shall procure that each of the Sponsor and Ocean Rig shall supply to the Facility Agent its interim
unaudited financial statements for each quarter of each financial year ending after the date of
this Agreement.
	 
	 	(e)	 	All audited financial statements of the Owner and
consolidated financial statements of each
of the Sponsor and Ocean Rig must be supplied as soon as they are available and in any event within 150 days of the end
of the relevant financial period and all unaudited financial statements for each quarter must be
supplied as soon as they are available and in any event within 60 days of the end of each relevant
financial period.






	15.2	 	Form of financial statements






	 	(a)	 	The Owner must ensure that each set of financial statements supplied under Clause 15.1 of this
Agreement fairly represents the relevant parties financial condition as at the date to which those
financial statements were drawn up.
	 
	 	(b)	 	The Owner must notify the Facility Agent of any change to the basis on which the audited
financial statements are prepared.
	 
	 	(c)	 	If requested by the Facility Agent, the Owner must supply or procure that the following are
supplied to the Facility Agent:






	 	(i)	 	a full description of any change notified under paragraph (b) above; and
	 
	 	(ii)	 	sufficient information to enable the Facility Agent to make a proper comparison between the
financial position shown by the set of financial statements prepared on




62









 












	 	 	 	the changed basis and its
most recent audited financial statements delivered to the Facility Agent under this Agreement.






	 	(d)	 	If requested by the Facility Agent, the Owner must enter into discussions for a period of not
more than 30 days with a view to agreeing to any amendments required to be made to this Agreement
to place the Facility Agent in the same position as it would have been in if the change had not
happened.
	 
	 	(e)	 	If no agreement is reached under paragraph (d) above on the required amendments to this
Agreement, the Owner shall ensure that its auditors or, as the case may be, the Owner specifies
those amendments; the certificate of the auditors will be, in the absence of manifest error,
binding on all the Parties.







 
15.3 Annual Budget and reports



	 	(a)	 	The Owner must supply to the Facility Agent, in electronic form by email attachment or hard
copy (and, if in hard copy, in sufficient copies for all of the Lenders), a draft Annual Budget for
each financial year within 14 days of its approval by the board of directors of the Owner and at
least one month prior to the start of the relevant financial year, such budget to be considered
and, if agreed by the Majority Lenders, approved in writing by the Facility Agent (acting
reasonably) within 21 days of receipt following which the draft Annual Budget shall become the
Annual Budget for the purposes of this Agreement. For this purpose if any Lender fails to respond
to a request to agree any such draft within 21 days it shall be deemed to have approved it.
	 
	 	(b)	 	In the event any draft Annual Budget is not approved by the Facility Agent, the Facility Agent
and the Owner shall consult and agree a revised Annual Budget. If a revised Annual Budget is not
agreed within 30 days, the Facility Agent (acting on the instructions of the Majority Lenders) and
the Owner shall agree to appoint a suitable expert to resolve any disputes they may have in respect
of the Annual Budget. If the Facility Agent and Owner can not agree on an expert, the Facility
Agent will apply to the London Maritime Arbitrators Association and the President of the London
Marine Arbitrators Association shall appoint an expert on their behalf. In each case, the written
determination of such expert in respect of any dispute, addressed to the Facility Agent and the
Owner, shall (except in the case of manifest error) be final and binding.
	 
	 	(c)	 	Until a revised Annual Budget has been agreed between the Owner and the Facility Agent in
accordance with this Clause 15.3, the amount of any Earnings to be transferred from the Proceeds
Account to the Operating Expenses Account or, as the case may be, the CAPEX Account shall continue
on the basis of the current (or, as the case may be, immediately previous) Annual Budget.
	 
	 	(d)	 	The Owner must promptly supply to the Technical Adviser, in electronic form by email attachment
or hard copy, quarterly (or if the Facility Agent decides, in consultation with the Owner, that a
monthly report is needed, monthly) technical reports (in the Pre-Completion Period) and quarterly
operating reports (in the Post-Completion Period) in form and substance satisfactory to the
Technical Adviser together with all such other information and documents which the Technical
Adviser reasonably requires to perform its Workscope and its obligations under the Technical
Proposal.
	 
	 	(e)	 	The Owner must procure that the Builder will give the Technical Adviser access to perform
periodic visits to the premises of the Builder and the Builder’s subcontractors in order to monitor
the construction of the Vessel and the materials and components to be used in the




63









 












	 	 	 	construction of
the Vessel and that the Builder, the Manager and the Classification Society will provide the
Technical Adviser with all such other information and documents which the Technical Adviser
reasonably requires to perform its Workscope and its obligations under the Technical Proposal.






	15.4	 	Access to Books and Records
	 
	 	 	Upon the request of the Facility Agent, the Owner shall provide the Facility Agent and any of its
representatives and professional advisers with access to, and permit inspection of, its books and
records, in each case at reasonable times and upon reasonable notice.
	 
	15.5	 	Information — miscellaneous
	 
	 	 	The Owner must supply to the Facility Agent, in electronic form by email attachments or hard copy
(and, if in hard copy, in sufficient copies for all of the Lenders), subject to any duty of
confidentiality which it may have to third parties (whom it will promptly approach in order to seek
any necessary consents where applicable):






	 	(a)	 	copies of all documents despatched by it to its creditors (other than trade creditors)
generally or any class of them at the same time as they are despatched;
	 
	 	(b)	 	copies of all reports provided to the Owner by the Manager pursuant to the Management
Agreement, in each case, within five (5) Business Days of receipt of such report by the Owner and
if, in the opinion of the Facility Agent (acting reasonably), any additional technical report is
necessary, the Owner will procure such report;
	 
	 	(c)	 	as soon as reasonably practicable on becoming aware of them, details of any litigation,
arbitration or administrative proceedings which are current, pending or, to the best of its
knowledge and belief, threatened against it and which, in each case, would have a Material Adverse
Effect (in the opinion of the Facility Agent acting on the instructions of the Majority Lenders);
	 
	 	(d)	 	as soon as reasonably practicable on request, such further information, in electronic form by
email attachments or hard copy (and, if in hard copy, in sufficient copies for all of the Lenders),
regarding the financial condition and operations of the Owner or regarding any matter relevant to,
or to any provision of, a Finance Document as the Facility Agent may reasonably request;
	 
	 	(e)	 	as soon as reasonably practicable on becoming aware of them, details of any event or
circumstance which is a Force Majeure Event;
	 
	 	(f)	 	promptly on becoming aware of them, details of any event which has a Material Adverse Effect;
	 
	 	(g)	 	as soon as they are available, copies of any notice of default, termination, material dispute
or claim (including notices provided by the Charterer under the terms of a Drilling Charter) made
against it under the Shipbuilding Contract, the Drilling Charter, any
Refund Guarantee or under the
Owner’s Shipbuilding Contract Guarantee or affecting the Vessel together with details of any action
it proposes to take in relation to the same and notice of any charterhire reduction or proposed
charterhire reduction under the terms of a Drilling Charter;
	 
	 	(h)	 	as soon as they are available, copies of any notice of default, termination or material claim
made against it under the Management Agreement together with details of any action it




64









 












	 	 	 	proposes to take in relation to the same and, upon becoming aware of the same, notification of any strikes or
industrial action taken or proposed to be taken by the Manager or its employees, subcontractors or
personnel from time to time which has or may reasonably be expected to have a Material Adverse
Effect;
	 
	 	(i)	 	promptly on becoming aware of them, details of any damage to or destruction of the Vessel
or any breakdown of any part of the Vessel, where the cost of repair or reinstatement is likely to
exceed US$10,000,000 or where the cumulative cost of repair or reinstatement of damage to or
destruction of the Vessel during the previous six months is likely to exceed US$10,000,000;
	 
	 	(j)	 	promptly on becoming aware of them, details of any proposal for an amendment or waiver of a
Related Contract other than amendments or waivers of an administrative or non-material nature; and
	 
	 	(k)	 	upon request by the Facility Agent, copies of all Transaction Authorisations (if any) obtained
by it.






	15.6	 	Pre-Completion period






	 	(a)	 	The Owner must promptly supply to the Facility Agent, in electronic form by email attachments
or hard copy (and, if in hard copy, in sufficient copies for all of the Lenders) any reports
received in relation to the construction of the Vessel provided by the Builder pursuant to Article
IV paragraph 7 of the Shipbuilding Contract.
	 
	 	(b)	 	The Owner must promptly, upon the earlier of (i) becoming aware of the same and (ii) the time
when a prudent owner ought reasonably to have become aware of the same, notify the Facility Agent
of:






	 	(i)	 	any breach (or attempted breach) of safety or security at the premises of the Builder which has
a Material Adverse Effect;
	 
	 	(ii)	 	any material claim it may have under any indemnity or provision for any Liquidated Damages
Payments under the Shipbuilding Contract;
	 
	 	(iii)	 	any reduction in hire payable under a Drilling Charter on account of a delay in delivery of
the Vessel to the Charterer; and
	 
	 	(iv)	 	any change or further change to the Scheduled Delivery Date.






	15.7	 	Notification of Default
	 
	 	 	Unless the Facility Agent has already been so notified, the Owner must notify the Facility Agent of
any Default, Potential Mandatory Prepayment Event or Mandatory Prepayment
Event (and the steps, if any, being taken to remedy it) promptly upon becoming aware of its
occurrence.
	 
	15.8	 	Year end
	 
	 	 	The Owner must not change its accounting period or auditors except with the consent of the Facility
Agent (acting in accordance with the instructions of the Majority Lenders) which shall not be
unreasonably withheld or delayed.





65









 











	15.9	 	Information provided to be accurate






	 	(a)	 	All financial and other information provided by the Owner under or in connection with any
Finance Document at the time when given will be true and not misleading in any material respect and
will not omit any material fact.
	 
	 	(b)	 	All financial and other information provided by third parties on behalf of the Owner under or
in connection with any Finance Document at the time when given will, to the best of the Owner’s
knowledge and belief, be true and not misleading in any material respect and will not omit any
material fact.






	15.10	 	Charter Termination Events
	 
	 	 	At all times during the Post-Completion Period, the Owner
shall (and shall procure that Ocean Rig
shall) promptly advise the Facility Agent of any Charter Termination Event of which it or they
become aware.
	 
	15.11	 	Calculation Certificate






	 	(a)	 	At least 15 Business Days prior to each Repayment Date, the Owner shall deliver a duly
completed Calculation Certificate to the Facility Agent signed by two of its authorised signatories
on its behalf:






	 	(i)	 	setting out the Debt Service Cover Ratio for the most recent Calculation Period; and
	 
	 	(ii)	 	certifying no Default, Mandatory Prepayment Event or Potential Mandatory Prepayment Event is
outstanding or, if a Default, Mandatory Prepayment Event or Potential Mandatory Prepayment Event is
outstanding, specifying the Default, Mandatory Prepayment Event or Potential Mandatory Prepayment
Event outstanding and the steps, if any, being taken to remedy it.






	 	(b)	 	Within seven Business Days of receiving a Calculation Certificate, the Facility Agent must
notify the Owner whether it agrees with the Debt Service Cover Ratio calculation set out in that
Calculation Certificate, otherwise the Facility Agent will be deemed to have accepted such Debt
Service Cover Ratio calculation.
	 
	 	(c)	 	If the Facility Agent does not agree with the Debt Service
Cover Ratio calculation set out in a
Calculation Certificate, the Facility Agent and the Owner shall consult, in good faith, to agree
the Debt Service Cover Ratio calculation as soon as possible. If the Debt Service Cover Ratio is
not agreed within ten Business Days of notification by the Facility Agent under paragraph (b)
above, the matter will be referred to the Owner’s auditor whose written determination, addressed to
the Facility Agent and the Owner, shall (except in the case of manifest error) be final and
binding.






	15.12	 	Know your customer requirements






	 	(a)	 	The Owner must promptly on the request of any Finance Party supply to that Finance Party any
documentation or other evidence which is reasonably requested by that Finance Party (whether for
itself, on behalf of any Finance Party or any prospective new Lender) to enable a Finance Party or
prospective new Lender to carry out and be satisfied with the results of all applicable know your
customer requirements.




66









 












	 	(b)	 	Each Lender must promptly on the request of the Facility Agent supply to the Facility Agent any
documentation or other evidence which is reasonably
required by the Facility Agent to carry out and be satisfied with the results of all know your
customer requirements.






	16.	 	GENERAL COVENANTS
	 
	16.1	 	General
	 
	 	 	The Owner agrees to be bound by the covenants set out in this Clause 16.
	 
	16.2	 	Authorisations
	 
	 	 	The Owner must promptly:






	 	(a)	 	obtain, maintain and comply with the terms; and
	 
	 	(b)	 	supply certified copies to the Facility Agent,






	 	 	of any authorisation required under any Applicable Law to enable it to perform its obligations
under, or for the validity, enforceability or admissibility in evidence of, any Finance Document.
	 
	16.3	 	Compliance with laws
	 
	 	 	The Owner must comply, and the Owner must procure that the Manager complies, in all material
respects with all Applicable Laws to which it is subject.
	 
	16.4	 	Pari passu ranking
	 
	 	 	The Owner must ensure that its payment obligations under the Finance Documents rank at least
pari passu with all its other present and future unsecured payment obligations, except for
obligations mandatorily preferred by law applying to companies generally.
	 
	16.5	 	Disposals






	 	(a)	 	The Owner must not (other than insofar as the same may be created or effected under the Finance
Documents), either in a single transaction or in a series of transactions and whether related or
not:






	 	(i)	 	sell, transfer or otherwise dispose of all or a substantial part of its assets;
	 
	 	(ii)	 	sell, transfer or otherwise dispose of any of its receivables on recourse terms;
	 
	 	(iii)	 	enter into any arrangement under which money or the benefit of a bank or other account
may be applied, set-off or made subject to a combination of accounts; or
	 
	 	(iv)	 	enter into any other preferential arrangement having a similar effect,






	 	 	in circumstances where the transaction might have a Material Adverse Effect.






	 	(b)	 	Paragraph (a) does not apply to any disposal:






	 	(i)	 	made in the ordinary course of trading on arm’s length terms;
	 
	 	(ii)	 	of obsolete assets; or




67









 












	 	(iii)	 	of assets (other than the Vessel) in exchange for other assets comparable or superior as to
type, value and quality.






	16.6	 	Security Interests
	 
	 	 	The Owner must not create or permit to subsist any Security Interest over any of its assets other
than Permitted Liens.
	 
	16.7	 	No other business assets or Financial Indebtedness
	 
	 	 	The Owner must not:






	 	(a)	 	engage in any business other than the direct ownership, operation and chartering of the Vessel
or any business incidental thereto;
	 
	 	(b)	 	cease to carry on its business;
	 
	 	(c)	 	own or acquire any asset other than the Vessel or any asset incidental to the ownership,
operation and chartering of the Vessel; or
	 
	 	(d)	 	incur any Financial Indebtedness other than:






	 	(i)	 	Financial Indebtedness incurred or permitted under the Finance Documents;
	 
	 	(ii)	 	any Financial Indebtedness by way of borrowing from the Sponsor for the purpose only of
posting any cash collateral which the Owner may from time to time be required to post under any of
the Swap Agreements provided that any such Financial Indebtedness is fully subordinated to the
rights and interests of the Finance Parties under the Finance Documents; or
	 
	 	(iii)	 	any Financial Indebtedness otherwise approved by the Facility Agent (acting on the
instructions of the Majority Lenders).






	16.8	Distributions






	 
	 	 	 	The Owner shall not make any Distributions, provided that the Owner may make Distributions of
funds released from the Equity Account pursuant to Clause 12.2(d) (Proceeds Account and Equity
Account) above.
	 






	16.9	Place of business






	 
	 	 	 	The Owner must maintain its registered office in the Marshall Islands and keep its corporate
documents at either its registered office or at the offices of its officers and will not
voluntarily establish, or do anything as a result of which it would be deemed to have voluntarily
established, a place of business in any country other than the Marshall Islands.
	 






	16.10	Mergers, guarantees and loans






	 	(a)	 	The Owner shall not enter into any amalgamation, demerger, merger or reconstruction that might
have a Material Adverse Effect.
	 
	 	(b)	 	Save in the ordinary course of business, the Owner must not incur or allow to be outstanding
any guarantee (including an indemnity or other assurance against loss) (a Relevant Guarantee) by it
in respect of any person and any Relevant Guarantee which would




68









 












	 	 	 	otherwise be permitted under this
paragraph (b) will not be permitted if the Owner’s obligations under the Relevant Guarantee are
secured by any of the Security Assets (save to the extent such security constitutes a Permitted
Lien).
	 
	 	(c)	 	The Owner must not be the creditor in respect of Financial Indebtedness other than:






	 	(i)	 	advances to crew;
	 
	 	(ii)	 	in connection with any spares or pooling arrangements (approved by the Facility Agent (acting
on the instructions of the Majority Lenders acting reasonably)) or sale of equipment relating to
the Vessel entered into by the Owner in the ordinary course of its business;
	 
	 	(iii)	 	deposits placed with banks or the providers of goods and services entered into by the Owner
in the ordinary course of its business; or
	 
	 	(iv)	 	pursuant to its obligations to a Swap Bank under a
Swap Agreement.






	 	(d)	 	The Owner must not create any Subsidiary provided that,
without prejudice to the provisions of Clauses 16.17 and 16.22 or any other provision of the Finance Documents, the Owner may create Subsidiaries, the sole purpose of those Subsidiaries being to act as the operating company and/or
the bareboat charterer of the Vessel, as a means for the Owner to
utilise any such Subsidiaries to operate for and/or charter the Vessel to a Charterer.






	16.11	 	Security
	 
	 	 	The Owner:






	 	(a)	 	without prejudice to Clause 16.12(a), shall procure that the Mortgage and any other security
conferred by it under any Security Document is registered as a first priority interest with the
relevant authorities within the period prescribed by Applicable Law and is maintained and perfected
with the relevant authorities;
	 
	 	(b)	 	shall at its own cost do all that it can to ensure that any Finance Document validly creates
the obligations and Security Interests which it purports to create; and
	 
	 	(c)	 	without limiting the generality of paragraph (a) above, shall at its own cost promptly
register, file, record or enrol any Finance Document with any relevant court or authority, pay any
stamp, registration or similar tax payable in respect of any Finance Document, give any notice or
take any other step which, in the reasonable opinion of the Facility Agent, is or has become
necessary for any Finance Document to be valid, enforceable or admissible in evidence or to ensure
or protect the priority of any Security Interest which it creates.






	16.12	 	Registration of the Vessel
	 
	 	 	The Owner shall, and shall procure that the Manager shall:






	 	(a)	 	procure and maintain, with effect from the Delivery Date, the valid and effective permanent
registration of the Vessel under the flag of the Marshall Islands or such other flag as is
satisfactory to the Facility Agent (acting on the instructions of the Majority Lenders (acting in
good faith but otherwise in their absolute discretion)), and shall ensure nothing is done or
omitted by the Owner and shall use reasonable endeavours to ensure that nothing is done or




69









 












	 	 	 	omitted
to be done by any third party by which the registration of the Vessel would or might be defeated or
imperilled;
	 
	 	(b)	 	not change the name or port of registration of the Vessel without the prior written consent of
the Facility Agent (acting on the instructions of the Majority Lenders) (such consent not to be
unreasonably withheld or delayed); and
	 
	 	(c)	 	ensure that the Vessel complies in all respects with Applicable Laws from time to time
applicable to vessels registered under the laws and flag of the Marshall Islands or such other flag (an
Alternative Flag) under which the Vessel may be registered from time to time in
accordance with this Agreement, provided that if at any time an Alternative Flag is not a signatory
to all International Maritime Organization Assembly resolutions and regulations to which the Marshall Islands is a
signatory, then the Owner shall ensure, and shall procure that the Manager ensures, that the
Alternative Flag issues a certificate of equivalency of the Vessel in respect of each such
International Maritime Organization Assembly resolution and regulation.






	16.13	 	Classification, maintenance and repair
	 
	 	 	The Owner shall, and shall procure that the Manager shall, at all times after the Delivery Date:






	 	(a)	 	maintain and preserve the Vessel in good working order and repair (ordinary wear and tear
excepted), seaworthy, in efficient operating condition and, in any event, to a standard at least
equivalent to vessels managed and/or operated by the Manager and the Sponsor’s group and the
recommendations of the Builder;
	 
	 	(b)	 	ensure that the Vessel is surveyed from time to time as required by the Classification Society
in which the Vessel is entered at that time;
	 
	 	(c)	 	maintain the highest classification of the Vessel with the Classification Society or, if such
classification is not available, with the highest equivalent classification in another
internationally recognised classification society of like standing acceptable to the Facility
Agent (acting on the instructions of the Majority Lenders), free of all overdue requirements and
overdue recommendations of that classification society or register;
	 
	 	(d)	 	maintain and keep up to date the Technical Records in English and in compliance with all
Applicable Laws relating to the Vessel and the requirements of the Classification Society;
	 
	 	(e)	 	maintain and keep the Software Records up to date;
	 
	 	(f)	 	comply in all material respects with all Software Licences and use its best endeavours to
procure that all Software Licenses are capable of assignment;
	 
	 	(g)	 	procure that all repairs to or replacement of any damaged, worn or lost parts or equipment
shall be effected in such manner (both as regards workmanship and quality of materials) as not to
materially diminish the value of the Vessel or cause damage to the Environment;
	 
	 	(h)	 	not remove any material part of the Vessel, any part or any other material item of equipment
installed on the Vessel unless the part or item so removed is forthwith replaced by a suitable part
or item which is in the same condition as or better condition than the part or item removed, is
free from any Security Interest or any right in favour of any person other than the Finance
Parties, and becomes on installation on the Vessel the property of the Owner and subject to the
security constituted by the relevant Security Document(s) provided that, for




70









 












	 	 	 	the avoidance of doubt, the Owner may install and remove equipment
owned by a third party if the equipment can be removed without any risk of damage to the Vessel or
the Environment and does not affect the class, flag or custody transfer certification; and
	 
	 	(i)	 	without prejudice to paragraph (h) not without prior written consent of the Facility Agent not
to be unreasonably withheld (acting on the instructions of the Majority Lenders), cause or permit
to be made any substantial change in the structure, machinery, equipment, control systems, type or
performance characteristics of the Vessel other than modifications required by the Classification
Society or Applicable Law.






	16.14	 	Lawful and safe operation
	 
	 	 	The Owner shall, and shall procure that the Manager shall, at all times after the Delivery Date:






	 	(a)	 	operate the Vessel and cause the Vessel to be operated in a manner consistent in all material
respects with any Applicable Law;
	 
	 	(b)	 	not cause or permit the Vessel to trade with, or within the territorial waters of, any country
in which her safety may be imperilled by exposure to terrorism;
	 
	 	(c)	 	not cause or permit the Vessel to be employed in any manner which will or may give rise to any
reasonable degree of likelihood that the Vessel would be liable to arrest, requisition,
confiscation, forfeiture, seizure, destruction or condemnation as prize;
	 
	 	(d)	 	not cause or permit the Vessel to be employed in any trade or business which is forbidden by
Applicable Law or is illicit or in carrying goods which are illicit or prohibited under any
Applicable Law;
	 
	 	(e)	 	in the event of hostilities in any part of the world (whether war be declared or not) not cause
or permit the Vessel to be carrying any contraband goods and/or trading in any zone after it has
been declared a war zone by any authority or by any of the Vessel’s war risks Insurers unless the
Vessel’s Insurers shall have confirmed to the Owner that the Vessel is held covered under the
Obligatory Insurances or under a government scheme that gives comparable protection for the
voyage(s) in question; and
	 
	 	(f)	 	not charter the Vessel with any foreign country or national of any foreign country which
is the subject of sanctions imposed by the United Nations or is specified by legislation or
regulations of the flag state under which the Vessel is registered and such that, if the earnings
or any part of the earnings were derived from such charter, that fact would render any Finance
Document or the security conferred by the Security Documents unlawful.






	16.15	 	Repair of the Vessel
	 
	 	 	Save in circumstances where the Insurers have agreed to cover the cost of the work or where the
Owner has demonstrated to the satisfaction of the Facility Agent that adequate reserves or security
are at the relevant time maintained or provided for, the Owner shall not, and shall procure that
the Manager shall not, at any time after the Delivery Date put the Vessel into the possession of
any person for the purpose of work being done upon her beyond the amount of US$15,000,000 or
equivalent), other than for classification or scheduled dry docking, unless such person shall have
given an undertaking to the Facility Agent not to exercise any lien on the Vessel or Obligatory
Insurances for the cost of that work or otherwise.




71









 












	16.16	 	Arrests and Liabilities
	 
	 	 	The Owner shall, and shall procure that the Manager shall, at all times after the Delivery Date:






	 	(a)	 	pay and discharge all obligations and liabilities whatsoever which have given or may give rise
to liens (other than Permitted Liens) on or claims enforceable against the Vessel and take all
reasonable steps to prevent a threatened arrest of the Vessel;
	 
	 	(b)	 	notify the Facility Agent promptly in writing of the levy or other distress on the Vessel or
its arrest, detention, seizure, condemnation as prize, compulsory acquisition or requisition for
title or use and (save in the case of compulsory acquisition or requisition for title or use or any
other event that would, with the passage of time, constitute a Total Loss of the Vessel) obtain the
release of the Vessel within twenty-one (21) days;
	 
	 	(c)	 	pay and discharge when due all dues, taxes, assessments, governmental charges, fines and
penalties lawfully imposed on or in respect of the Vessel or the Owner except those which are being
disputed in good faith by appropriate proceedings (and for the payment of which adequate reserves
or security are at the relevant time maintained or provided or for which indemnity or liability
insurance cover for at least the full amount in dispute has been obtained by the Owner from
underwriters or insurance companies approved by the Facility Agent (acting on the instructions of
the Majority Lenders acting reasonably)) and provided that the continued existence of such dues,
taxes, assessments, governmental charges, fines or penalties does not give rise to any reasonable
degree of likelihood that
the Vessel would be liable to arrest, requisition, confiscation, forfeiture, seizure, destruction
or condemnation as prize; and
	 
	 	(d)	 	pay and discharge all other obligations and liabilities whatsoever in respect of the
Vessel and the Obligatory Insurances except those which are being disputed in good faith by
appropriate proceedings (and for the payment of which adequate reserves or security are at the
relevant time maintained or provided or for which indemnity or liability insurance cover for at
least the full amount in dispute has been obtained by the Owner from underwriters or insurance
companies approved by the Facility Agent (acting on the instructions of the Majority Lenders
(acting reasonably)) and provided that the continued existence of those obligations and liabilities
in respect of the Vessel and the Obligatory Insurances does not give rise to any reasonable degree
of likelihood that the Vessel would
be liable to arrest, requisition, confiscation, forfeiture, seizure, destruction or condemnation as
prize and provided always that the Vessel remains properly managed and insured at all times in
accordance with the terms of this Agreement.






	16.17	 	Related Contracts
	 
	 	 	The Owner shall:






	 	(a)	 	exercise its rights and comply with its material obligations under each Finance Document and
Related Contract to which it is a party;
	 
	 	(b)	 	not without the consent of the Facility Agent (acting on the instructions of the Majority
Lenders acting reasonably):






	 	(i)	 	make or enter into (and shall procure that the Sponsor, Ocean Rig and the Manager shall not make or enter
into) any amendments, changes or variations to, or assign, transfer, terminate, suspend or abandon
any of the Related Contracts (and to the extent necessary it will withhold its consent to any such
amendment, assignment,




72









 












	 	 	 	transfer, termination, suspension or abandonment) other than an amendment,
change or variation of a non- material or administrative nature (and, for the avoidance of doubt,
any amendments, changes or variations to the Shipbuilding Contract which would or may delay the
Delivery Date by 3 months or more would in all cases be deemed a “material” amendment, change or
variation);
	 
	 	(ii)	 	take any action, enter into any document or agreement or omit to take any action or to enter
into any document or agreement which a reasonable shipowner in the position of the Owner could
reasonably be expected to know should be taken or entered into which, in any such case, would cause
any Related Contract to be terminated or to cease to remain in full force and effect and shall use
all reasonable endeavours to procure that each other party to any Related Contract does not take
any action, enter into any document or agreement or omit to take any action or to enter into any
document or agreement which would, or could reasonably be expected to, cause any Related Contract
to cease to remain in full force and effect;
	 
	 	(iii)	 	release the Builder or the Charterer from any of its material obligations under the
Shipbuilding Contract or the Drilling Charter, as the case may be; or
	 
	 	(iv)	 	permit (and will procure that no Other Owner shall permit) any amendments, changes or
variations to, or assignments, transfers, termination, suspension or abandonment of any of the
Other Shipbuilding Contract (and to the extent necessary it will procure the Other Owner will
withhold its or their consent to any such amendment, change, variation, assignment, transfer,
termination, suspension or abandonment) other than an amendment of a non-material or administrative
nature; and






	 	(c)	 	not exercise its rights under Article I paragraph 5 of the Shipbuilding Contract to
approve any relevant subcontractor under the Shipbuilding Contract without the Facility Agent’s
(acting on the instructions of the Majority Lenders) prior written consent.






	16.18	 	Environment
	 
	 	 	The Owner shall, and shall procure that the Manager shall, at all times after the Delivery Date:






	 	(a)	 	comply in all material respects with all applicable Environmental Laws and Environmental
Approvals including, without limitation, requirements relating to the establishment of financial
responsibility (and shall require that all Environmental Affiliates of the Owner comply in all
material respects with all applicable Environmental Laws and obtain and comply with all required
Environmental Approvals, insofar as such Environmental Laws and Environmental Approvals relate to
the Vessel or her operation or her carriage of cargo);
	 
	 	(b)	 	comply in all material respects with its obligations under and in accordance with health and
safety requirements of a Drilling Charter; and
	 
	 	(c)	 	promptly upon becoming aware notify the Facility Agent of:






	 	(i)	 	any Environmental Claim in excess of US$2,500,000 which is current or, to its knowledge,
pending or threatened against it or any Environmental Affiliate relating to the Vessel or her
operation or her carriage of cargo; or




73









 












	 	(ii)	 	any fact or circumstances reasonably likely to give rise to an Environmental Claim in excess
of US$2,500,000 against it or any Environmental Affiliate relating to the Vessel or her operation
or her carriage of cargo; or
	 
	 	(iii)	 	any suspension, revocation or modification of any Environmental Approval obtained by the
Owner, the Manager or the Charterer relating to the Vessel or her
operation or her carriage of
cargo; or
	 
	 	(iv)	 	any Release of Hazardous Materials by or in respect of the Vessel or caused by the Vessel or
its operations which could lead to an Environmental Claim in excess of US$250,000,






	 	 	 	and in each case such notification shall take the form of a certificate of an officer of the Owner
or of the Owner’s agents specifying in reasonable detail the nature of the event or circumstances.






	16.19	 	Information regarding the Vessel






	 	(a)	 	The Owner shall upon becoming aware of the same, and shall procure that the Manager shall upon
the earlier of (i) becoming aware of the same and (ii) the time when a
prudent manager ought reasonably to have become aware of the same, at all times after the Delivery
Date:






	 	(i)	 	promptly notify the Facility Agent of the occurrence of any accident, casualty or other event
which has caused or resulted in or may cause or result in the Vessel being or becoming a Total
Loss;
	 
	 	(ii)	 	promptly notify the Facility Agent of any requirement or recommendation made by any
Insurer or the Classification Society or by any competent authority which is not complied with in a
timely manner, disregarding any matter which cannot reasonably be considered to be material;
	 
	 	(iii)	 	promptly notify the Facility Agent of any intended dry-docking of the Vessel (whether routine
or otherwise);
	 
	 	(iv)	 	promptly notify the Facility Agent of any claim for a material breach of the ISM Code being
made in connection with the Vessel or its operation;
	 
	 	(v)	 	promptly notify the Facility Agent of any claim for a material breach of the ISPS Code being
made in connection with the Vessel or its operation;
	 
	 	(vi)	 	give to the Facility Agent from time to time on request such information, in electronic form
by email attachments or hard copy, as the Facility Agent may reasonably require regarding the
Vessel, its employment, position and engagements or regarding the Obligatory Insurances;
	 
	 	(vii)	 	provide the Facility Agent with copies of the classification certificate of the Vessel and of
all periodic damage or survey reports on the Vessel which the Facility Agent may reasonably
request;
	 
	 	(viii)	 	promptly notify the Facility Agent when a condition of class is applied by the
Classification Society;




74









 












	 	(ix)	 	promptly notify the Facility Agent if the Vessel is detained by any port, governmental or
quasi-governmental authority;
	 
	 	(x)	 	promptly notify the Facility Agent if the flag state or the Classification Society refuse to
issue or withdraw any trading certification;
	 
	 	(xi)	 	promptly notify the Facility Agent of any fire on board the Vessel which requires the use of
fixed fire systems;
	 
	 	(xii)	 	promptly notify the Facility Agent of any collision or grounding of the Vessel;
	 
	 	(xiii)	 	promptly notify the Facility Agent if the Vessel is taken under tow other than in respect of
the routine operation of the Vessel;
	 
	 	(xiv)	 	promptly notify the Facility Agent of any death or serious injury to any person which occurs
on board the Vessel;
	 
	 	(xv)	 	subject to any applicable restriction under a Drilling Charter give to the Facility Agent
and its duly authorised representatives (at their own risk and expense) reasonable access to the
Vessel but without interruption to her use or operation for the purpose of conducting on board
inspections and/or surveys of the Vessel and the Technical Records;
	 
	 	(xvi)	 	if the Facility Agent reasonably believes an Event of Default may have occurred and is
continuing, procure that the Facility Agent and its duly authorised representatives shall upon
request be granted the right to inspect the records kept in respect of the Vessel by the
Classification Society; and
	 
	 	(xvii)	 	if the Facility Agent reasonably believes an Event of Default may have occurred and is
continuing, furnish to the Facility Agent from time to time upon reasonable request certified
copies of the ship’s log in respect of the Vessel.






	 	(b)	 	The Owner shall, upon becoming aware of the same, during the Pre-Delivery Period, notify the
Facility Agent of any accident, casualty or other event which has caused or resulted in or may
cause or result in the Vessel as it is then constructed becoming a Total Loss or being reasonably
considered as beyond economic repair.






	16.20	 	Management
	 
	 	 	The Owner shall procure at all times after the Delivery Date that the Vessel is managed by the
Manager (except with the prior written consent of the Facility Agent (acting on the instructions of
the Majority Lenders acting reasonably)).
	 
	16.21	 	Proceeds from sale or Total Loss of the Vessel






	 	(a)	 	The Owner shall procure that the proceeds from a sale or Total Loss of the Vessel (and during
the Pre-Delivery Period, any proceeds from the Vessel under construction or buyer’s supplies being
deemed a total loss or being reasonably considered beyond economic repair) shall promptly upon
receipt by the Owner be paid to the Security Trustee for application in accordance with clause 10
of the DPP.
	 
	 	(b)	 	For so long as the Owner holds any such proceeds as referred to in paragraph (a), it shall do
so on trust for the Security Trustee.





75









 











	 	(c)	 	The Owner will not sell or agree to sell the Vessel and will procure that the Sister Owner will
not sell or agree to sell the Sister Vessel unless the Owner can demonstrate to the Facility Agent
to its satisfaction that:






	 	(i)	 	the Owner will upon such sale have sufficient funds to repay the Loans in full and all other
amounts outstanding hereunder in the case of the sale of the Vessel or under Clause
6.3 (Mandatory prepayment amount — Sister Vessel) in the case of a sale of the Sister Vessel; and
	 
	 	(ii)	 	in the case of the Sister Vessel, the Owner will upon such sale be in compliance with the
Leverage Ratio.






	16.22	 	Charters






	 	(a)	 	The Owner shall not let, or permit to be let, the Vessel on demise, time, consecutive voyage or voyage charter for
any period or to any person other than to a Charterer under a time charter party (a Drilling
Charter) in terms satisfactory to the Facility Agent (acting on the instructions of the Majority
Lenders) with an Approved Charterer and, other than in respect of the Petrobras Charter, with an Approved Rate.






	 	 	For the purposes of this paragraph (a):
	 
	 	 	Approved Charterer means (i) solely with respect to the Petrobras Charter, Petrobras Tanzania or
(ii) any other counterparty approved by the Facility Agent (acting on the
instructions of all of the Lenders) and which, unless otherwise agreed by the Facility Agent
(acting on the instructions of all of the Lenders), is not on negative watch and has (or who
provides a Charterer Parent Guarantee by its Holding Company which is not on negative watch and
which has) a rating of BBB or higher from Moody’s or a rating of Baa3 or higher from S&P;
	 
	 	 	Approved Rate means a time charter party in respect of which:






	 	(i)	 	for a time charter period of 2 years or more (but less than 3 years), the daily rate on its own
results in a minimum annual projected Net Cash Flow of US$116,000,000 and the minimum daily rate is
US$545,000;
	 
	 	(ii)	 	for a time charter period of 3 years or more (but less than 5 years), the daily rate on its
own results in a minimum annual projected Net Cash Flow of US$129,000,000 and the minimum daily
rate is US$550,000; or
	 
	 	(iii)	 	for a time charter period of 5 years or more, the daily rate on its own results in a minimum
annual projected Net Cash Flow of US$116,000,000 and the minimum
daily rate is US$510,000,






	 	 	and the amount projected to be the Net Cash Flow will be as estimated by the Owner and the Manager
and approved by the Facility Agent.






	 	(b)	 	The Owner shall procure that on or prior to the Delivery Date the counterparty to
Petrobras Tanzania under the Petrobras Charter enters into the deed of assignment of earnings as
set out in Clause 16.35(c)(i) below.




76









 












	 	(c)	 	The Owner shall (i) at least twelve (12) months prior to the expiry date (howsoever described)
of any Drilling Charter (other than the Petrobras Charter) and (ii) at least six (6) months prior
to the expiry date (howsoever described) of the Petrobras Charter:






	 	(i)	 	procure that a replacement Drilling Charter is entered into having a minimum term
(excluding any optional extensions) of 2 years;
	 
	 	(ii)	 	execute a deed of assignment of time charter and earnings in substantially the same form as
the Charter Assignment and shall procure that any notices, and shall use best
efforts to procure that any acknowledgements, thereto are duly
executed by the relevant parties to them; and

	 
	 	(iii)	 	provide a tax opinion from its tax advisers (which may be disclosed to the Finance
Parties) in respect of potential withholding and income tax payable under the Transaction Documents
in form and substance satisfactory to each of the Finance Parties.






	 	(d)	 	The Owner shall not:






	 	(i)	 	allow the Vessel to be sub-chartered by any Charterer without the consent of the Facility Agent
not to be unreasonably withheld (acting on the instructions of the Majority Lenders); or
	 
	 	(ii)	 	permit any transfer of Charterer’s rights and obligations under a Drilling Charter without the
prior written consent of the Facility Agent (acting on the instructions of all of the Lenders).






	16.23	 	Breach or Termination of Drilling Charter or Management Agreement






	 	(a)	 	In the event of the occurrence at any time during the Post-Completion Period of (i) one of the
events described in Clauses 6.2(e) or 6.2(f) which would otherwise give rise to an immediate
Mandatory Prepayment Event or (ii) an Event of Default set out in Clauses 18.6 (Insolvency), 18.7
(Insolvency proceedings), 18.8 (Creditors’ process), 18.9 (Cessation of business), 18.10 (Failure
to pay final judgment) and 18.11 (Material adverse change) in respect of the Charterer or the
Manager only, then, subject to the conditions set out in Clause 16.23(b) below, no Mandatory
Prepayment Event or Event of Default shall immediately arise and the Owner shall have the
opportunity to cure the relevant default, breach or event (including by proposing a substitute
charterer or manager) for a period of three (3) months from the date the relevant event or Event or
Default occurs or, if later, the date that a prudent owner could reasonably be expected to have
become aware of the occurrence of the relevant event or Event of Default (provided
always that for the purposes of this paragraph (a), the Owner shall in any event be deemed to have
become aware of the relevant event or Event of Default within thirty (30) days of the occurrence of
such event or Event of Default) (the Cure Period);
	 
	 	(b)	 	The right of the Owner to effect a cure and the postponement of the relevant Mandatory
Prepayment Event or Event of Default (as the case may be) pursuant to Clause 16.23(a) above shall
be available only if:






	 	(i)	 	there is no other Default existing at the time when the relevant event or Event of Default
referred to in Clause 16.23(a) arises and no such other Default occurs at any time during the Cure
Period; and






77











 






	 	(ii)	 	any substitute charterer or manager and/or substitute charter or management agreement
proposed by the Owner as the means of effecting a cure satisfies the terms and conditions of Clause
16.22 (in the case of a substitute charterer and/or charter) and the terms and conditions of Clause
16.24 (in the case of a substitute manager and/or management agreement); and
	 
	 	(iii)	 	the Owner procures that on the earlier of (i) the time at which Owner becomes aware of the
occurrence of an Event of Default or the relevant event, or (ii) 30 days after the occurrence of an
Event of Default or the relevant event referred to in Clause 16.23(a), there is deposited into the
Debt Service Reserve Account such additional amount as will ensure that the balance standing to the
credit of the Debt Service Reserve Account following such deposit is equal to at least the amount
required to pay the aggregate amount of interest and principal repayments accruing under this
Agreement during the period of nine (9) months following the date of such deposit. The Owner shall
not be entitled to use any funds then standing to the credit of any of the Accounts to effect such
deposit.






	 	(c)	 	If the Owner proposes to enter into a substitute charter or substitute management agreement,
the Owner shall, in relation to a substitute charter, comply fully with all of the provisions of
Clause 16.22 and, in relation to a substitute management agreement, the Owner shall, upon the
execution of the substitute management agreement, execute a security assignment of such substitute
management agreement together with all notices and acknowledgements thereto all in the same form
(mutatis mutandis) as the then existing security over the Management Agreement or otherwise in
form and substance satisfactory to the Majority Lenders.
	 
	 	(d)	 	For the avoidance of doubt, should any of the conditions set out in Clause 16.23(b) not be, or
cease to be, met, or should the Owner not effect a cure of the relevant breach, default or event
within the Cure Period, the relevant Mandatory Prepayment Event or, as the case may be, Event of
Default shall immediately arise and the Finance Parties shall be all of the rights flowing
therefrom.
	 
	 	(e)	 	If the Owner effects a cure of the relevant breach, Event of Default or other event within the
Cure Period pursuant to this Clause 16.23, the Owner may withdraw any such additional amount
deposited into the Debt Service Reserve Account in accordance with Clause 1 6.23(b)(iii).






	16.24	 	Management Agreement
	 
	 	 	The Owner shall ensure that the Management Agreement in respect of the Vessel remains in full force
and effect until the Final Maturity Date with the Manager or such other counterparty approved by
the Facility Agent (acting on the instructions of the Majority Lenders). The Management Agreement
shall contain provisions obliging the Manager to supervise the construction of the Vessel on behalf
of the Owner.
	 
	16.25	 	ISM Code
	 
	 	 	The Owner shall, and shall procure that the Manager shall:






	 	(a)	 	at all times after the Delivery Date comply, and be responsible for compliance by itself and by
the Vessel, with the mandatory requirements of the ISM Code;





78









 





	 	(b)	 	at all times after the Delivery Date ensure that the Vessel has a valid Safety Management
Certificate (or, following delivery until a final certificate is issued, a valid interim Safety
Management Certificate) which is held on board the Vessel and that the Manager holds a valid
Document of Compliance for the Vessel, a copy of which is held on board the Vessel;
	 
	 	(c)	 	promptly notify the Facility Agent of any actual or, upon becoming aware of the same,
threatened withdrawal of an applicable Safety Management Certificate or Document of Compliance;
	 
	 	(d)	 	promptly notify the Facility Agent of the identity of the person ashore designated for the
purposes of paragraph 4 of the ISM Code and of any change in the identity of that person; and
	 
	 	(e)	 	promptly upon becoming aware of the same notify the Facility Agent of the occurrence of any
accident or major non-conformity requiring action under the ISM Code.






	16.26	 	ISPS Code
	 
	 	 	The Owner shall, and shall procure that the Manager shall, at all times after the Delivery Date
comply and be responsible for compliance by itself and by the Vessel with the mandatory
requirements of the ISPS Code, and ensure that the Vessel has a valid International Ship Security
Certificate.
	 
	16.27	 	Delivery of Vessel
	 
	 	 	If the Owner is required by the terms of the Shipbuilding Contract to accept delivery of the Vessel
from the Builder, then the Owner will exercise all rights it has under the Drilling Charter in
place at such time to require the Charterer to take delivery of the Vessel under such Drilling
Charter.
	 
	16.28	 	Construction supervision






	 	(a)	 	The Owner shall give to the Facility Agent and the Technical Adviser notice of any meetings of
the Owner or the Owner’s representatives with the Builder or between the Owner or the Owner’s
representatives and any Charterer or the Charterer’s representatives where material divergence from
the Specification (as defined in the Shipbuilding Contract) is being discussed. Following any such
meeting, the Owner shall notify the Facility Agent and the Technical. Adviser of the outcome of such
meeting. Such advance notice and notice of the outcome shall be contained in the quarterly
technical reports referred to in Clause 15.3(d).
	 
	 	(b)	 	The Owner shall make reasonable efforts to obtain the Builder’s consent so that the Facility
Agent (at the Facility Agent’s own risk and expense) or its representative has a right to attend,
in a capacity as an observer only, the shipyard on an occasional basis and to be present at the sea
trials and first drill trial of the Vessel.
	 
	 	(c)	 	The Owner will give reasonable notice to the Facility Agent of the time and location of any of
the meetings, trials and voyages referred to in paragraph (b) above.






	16.29	 	Construction Milestones






	 	(a)	 	Project milestone for Instalment Loan 2:
	 
	 	•	 	start of steel cutting for the Vessel




79









 












	 	(b)	 	Project milestones for Instalment Loan 3:
	 
	 	•	 	start of keel laying for Vessel
	 
	 	(c)	 	Project milestones for Delivery Loan:
	 
	 	•	 	tender of Vessel for Delivery






	16.30	 	Tax affairs
	 
	 	 	The Owner must:






	 	(a)	 	promptly file all Tax reports and returns required to be filed by it in any jurisdiction; and
	 
	 	(b)	 	promptly pay all Taxes or, if any Tax is being contested in good faith and by appropriate
means, ensure an adequate reserve is set aside for payment of that Tax.






	16.31	 	Annex VI (Regulations for the Prevention of Air Pollution from Ships) to MARPOL
	 
	 	 	The Owner shall, and shall procure that the Manager shall, at all times after the Delivery Date
comply and be responsible for compliance by itself and by the Vessel with mandatory requirements of
Annex VI (Regulations for the Prevention of Air Pollution from Ships) to MARPOL, and ensure that
the Vessel has a valid International Air Pollution Prevention Certificate.






	16.32	 	Oil Pollution Act
	 
	 	 	For so long as the Vessel is operated in the territorial waters of the United States of America,
the Owner shall and/or shall procure the Charterer shall, comply with the requirements of all
mandatory United States laws, regulations and requirements (including United States Coastguard
regulations applicable to the Vessel and including for the avoidance of doubt any requirement to
have a valid and current Certificate of Financial Responsibility pursuant to the United States Oil
Pollution Act 1990) in relation to the operation and navigation of the Vessel in force at the
relevant time in the relevant area(s) of the United States of America.
	 
	16.33	 	Leverage Ratio






	 	(a)	 	The Owner will not permit the Leverage Ratio from time-to-time to be lower than 125 per cent,
such Leverage Ratio to be tested as provided in paragraph (c) below, provided that during the six
month period prior to the expiry date (howsoever described) of any Drilling Charter (the Drilling
Charter Final Period) the Owner will not permit the Leverage Ratio from time-to-time to be lower
than 140 per cent.
	 
	 	(b)	 	If on any determination date the Leverage Ratio is less than 125 per cent or, during the
Drilling Charter Final Period, 140 per cent, the Owner will immediately following a request of the
Facility Agent to do so:






	 	(i)	 	prepay such amount of the Loans as will ensure that the Leverage Ratio is not less than or
equal to 125 per cent, or, during the Drilling Charter Final Period, 140 per cent; or
	 
	 	(ii)	 	provide or cause to be provided to the Facility Agent such additional funds into the Debt
Service Reserve Account as is necessary to bring the Leverage Ratio equal to




80









 






	 	 	 	or not less than 125 per cent, or, during the Drilling Charter Final Period, 140 per cent; or
	 
	 	(iii)	 	provide such additional security, in all respects satisfactory to the Facility Agent (acting
on the instructions of the Majority Lenders), such that the Leverage Ratio is not less than or
equal to 125 per cent, or, during the Drilling Charter Final Period, 140 per cent.






	 	 	For the purposes of determining the Leverage Ratio, the additional security shall have attributed
to it such value as the Facility Agent (acting on the instructions of the Majority Lenders)
determines or in the case of additional security constituted by cash, its full value.






	 	(c)	 	The Facility Agent shall be entitled to test such Leverage Ratio as of:






	 	(i)	 	the Final Completion Date;
	 
	 	(ii)	 	each anniversary thereof;
	 
	 	(iii)	 	the first date of any Drilling Charter Final Period;
	 
	 	(iv)	 	upon the notice of the Sister Owner of its intention to sell a Vessel; and
	 
	 	(v)	 	at any time on notice from the Facility Agent after the occurrence of a Default which is
continuing.






	 	(d)	 	The Owner will procure a valuation on the basis described in the definition of Market Value on
or before (but dated not more than thirty (30) days prior to) the date on which Leverage Ratio is
to be calculated or in the case of paragraph (c) (i) promptly on demand and provide such valuation
to the Facility Agent who will verify such valuation by reference to the information provided by
the Owner.
	 
	 	(e)	 	The Owner will procure in favour of the Facility Agent and the Approved Brokers, all such
information, as they may reasonably (having regard to the use and operation of the Vessel) require
in order to effect such valuations.
	 
	 	(f)	 	All valuations shall be at the expense of the Owner.






	16.34	 	Sponsor’s shares
	 
	 	 	The Owner shall procure at all times during the Security Period that the shares of the Sponsor will
remain listed on NASDAQ.
	 
	16.35	 	Petrobras Charter
	 
	 	 	On or before the Delivery Date the Owner shall:






	 	(a)	 	provide the Facility Agent with full details of each current and/or proposed “Consortium Party”
and each known and/or potential “Country” in which drilling operations will be conducted under the
Petrobras Charter (as those terms are defined in the Petrobras Charter);
	 
	 	(b)	 	enter into and procure that all other relevant parties enter into such documentation as the
Facility Agent (acting on the instructions of all of the Lenders) considers necessary or desirable
(including, without limitation, security documentation and documentation to amend this Agreement)
in order to effect any Petrobras Charter transfer and/or bareboat





81









 





	 	 	 	chartering arrangements required as a result of Ocean Rig (rather than the Owner) entering into the
Petrobras Charter, without materially affecting the Lenders’ position with regard to tax, cash
flows, charterer credit or security;
	 
	 	(c)	 	provide and procure that all other relevant parties provide in favour of the Security Trustee,
on behalf of the Secured Parties:






	 	(i)	 	a deed of assignment of earnings in relation to the Petrobras Charter (and shall procure that
any notices, and shall use best efforts to procure that any acknowledgements, thereto are duly
executed by the relevant parties to them);
	 
	 	(ii)	 	a first priority assignment of time charter and earnings by way of security over all of the
right, title and interest of the Owner and/or any of its Affiliates in any bareboat charter as
referred to in Clause 16.35(b) above (and shall procure that any notices, and shall use best
efforts to procure that any acknowledgements, thereto are duly executed by the relevant parties to
them); and
	 
	 	(iii)	 	tax opinions from its tax advisers in respect of all relevant jurisdictions (which may be
disclosed to the Finance Parties) in respect of potential withholding and income tax payable under
the Transaction Documents and any bareboat charter as referred to in Clause 16.35(b) above, in form
and substance satisfactory to each of the Finance Parties,






	 	 	all such documentation and arrangements referred to in Clauses 16.35(b) and 16.35(c) being on terms
and in form satisfactory to the Facility Agent (acting on the instructions of all of the Lenders).
	 
	16.36	 	Delivery General Assignment
	 
	 	 	On or prior to the Delivery Date, the Owner shall ensure that the form of the Delivery General
Assignment to be executed in connection with the Delivery Loan is amended (in form and substance
satisfactory to the Facility Agent) to include:






	 	(a)	 	an assignment absolutely, subject to a proviso for re-assignment on redemption, of all of the
Owner’s rights in respect of the Operational Software, the Software Licences and the Software
Records; and
	 
	 	(b)	 	a chattel mortgage in relation to the Technical Records.






	17.	 	INSURANCES
	 
	17.1	 	Scope of Obligatory Insurances
	 
	 	 	The Owner shall:






	 	(a)	 	report on and monitor the Builder’s compliance with the Construction Insurances as detailed in
Article XVII of the Shipbuilding Contract and report on and confirm its compliance with the terms
of the Construction Insurances in respect of the Vessel and the equipment the subject of the
Shipbuilding Contract and the Buyer Supplies (as such term is defined in the Shipbuilding
Contract). The Owner shall procure that its Buyer Supplies are
insured for all risks of physical
loss or damage as is typically insured, and that the Owner is insured for
protection and indemnity risks during sea trials either under the Builder’s insurance policy or, if
this is not possible, the Owner shall have protection and indemnity insurance effective from the
commencement of the sea trials for an amount not less than US$300,000,000 (the




82









 






	 	 	 	amount to be reviewed and mutually agreed to be reduced if the Owners’ liability during the sea
trials is less than the above amount). The Owner shall also have general third party liability
insurance effective from the commencement of the sea trials for not less than US$25,000,000 to the
extent such insurance policy will be available;
	 
	 	(b)	 	at all times after the Delivery Date keep the Vessel insured in the Required Insurance Amount,
with a deductible of no more than US$15,000,000, in Dollars against fire and usual marine risks
(including Excess Risks), and if requested by the Facility Agent all spares, stores and other
property held elsewhere than on the Vessel against all risks of physical loss or damage as is
typically insured, in each case in the name of the Owner and with the interest of the Security
Trustee noted as mortgagee or assignee with underwriters or insurance companies approved by the
Facility Agent and (as applicable) through brokers approved by the Facility Agent (acting on the
instructions of the Majority Lenders), and by policies in form and content approved by the Facility
Agent (acting on the instructions of the Majority Lenders);
	 
	 	(c)	 	at all times after the Delivery Date keep the Vessel insured in at least the Required Insurance
Amount in the same manner as above against war risks (including, without limitation), (a) those
risks covered by the standard form of English marine policy with Institute War and Strike Clauses
(Time) (1/10/83) attached or similar cover and (b) war, terrorist or similar protection and
indemnity risks cover excluded from the protection and indemnity risks covered by the entry of the
Vessel with the relevant protection and indemnity association by reason of any exclusion clauses
contained in such entry, and all spares, stores, and other property held elsewhere than on the
Vessel against, at the minimum, riots, strikes, civil commotion and terrorism, in each case either:






	 	(i)	 	with underwriters or insurance companies approved by the Facility Agent (acting on the
instructions of the Majority Lenders) and by policies in form and content approved by the Facility
Agent (acting on the instructions of the Majority Lenders); or
	 
	 	(ii)	 	by entering the Vessel in an approved war risks association;






	 	(d)	 	at all times after the Delivery Date keep, or procure the Charterer keeps the Vessel entered in
an approved protection and indemnity association against all risks as are normally covered by such
protection and indemnity association, including without limitation, pollution risks, the proportion
not recoverable in case of collision under the running down clause inserted in the ordinary Hull
and Machinery policies and Specialist Operations coverage, in the name of the Owner for claims
which the Owner would have incurred had they been pursued against it, such cover to be for:






	 	(i)	 	the higher of the minimum amount stipulated in any Drilling Charter and US$500,000,000 or such
other amount of cover against P&I including pollution risks as shall at any time be comprised in
the basic entry of the Vessel with either a protection and indemnity association which is a member
of either the International Group of P&I Clubs (or any successor organisation designated by the
Facility Agent for this purpose); or
	 
	 	(ii)	 	if the International Group or any such successor ceases to exist or ceases to provide or
arrange any cover for pollution risks (or any supplemental cover for pollution risks over and above
that afforded by the basic entry of the Vessel with its protection and indemnity association), such
aggregate amount of cover against pollution risks as shall be generally available on the open
market and by basic entry with a






83









 








	 	 	 	protection and indemnity association for ships of the same type, size, age and flag as the Vessel, provided that, if the Vessel has ceased trading or is in lay up and in either case has unloaded all
cargo, the level of pollution risks cover afforded by ordinary protection and indemnity cover
available through a member of the International Group or such successor organisation or, as the
case may be, on the open market in such circumstances shall be sufficient for such purposes;
	 
	 	(e)	 	at all times following the Final Completion Date, maintain in full force and effect loss of
hire insurance, on a daily amount fixed and agreed basis, in respect of the Vessel subject to a
deductible of 45 days (or minimum deductible available by loss of hire underwriters) per incident
or occurrence and for a minimum indemnity period of 180 days with underwriters or insurance
companies approved by the Facility Agent (acting on the instructions of the Majority Lenders) in
form and content approved by the Facility Agent (acting on the instructions of the Majority
Lenders), provided always that the obligation of the Owner to maintain such loss of hire insurance
shall cease if a prudent owner of a vessel similar to the Vessel and employed on a similar basis,
acting reasonably, would consider the cost of the loss of hire insurance to be commercially
unacceptable;
	 
	 	(f)	 	at all times following the Final Completion Date, if and as requested from time to time by the
Facility Agent, to maintain in full force and effect insurance(s) in respect of such other matters
of whatsoever nature and howsoever arising in respect of which insurance would be available to a
prudent owner of the Vessel; and
	 
	 	(g)	 	comply or procure compliance with the terms and conditions of the Obligatory Insurances
(including, but not limited to, making any declarations required by such insurances in order to
maintain cover for operating within any waters where it is required to be located under a Drilling
Charter, which declarations the Owner shall promptly copy to the Facility Agent), not do, consent
to or permit any act or omissions which might invalidate or render unenforceable the whole or any
part of the Insurances.






	17.2	 	Mortgagee’s interest and additional perils insurances
	 
	 	 	The Facility Agent shall be entitled, from time to time and at the Owner’s cost and expense, to
effect from the Delivery Date, maintain and renew all or any of the following insurances in the
Required Insurance Amount, and on such terms, through such insurers and in such manner as the
Facility Agent (acting on the instructions of the Majority Lenders) may from time to time consider
appropriate:






	 	(a)	 	a mortgagee’s interest marine insurance providing for the indemnification of the Finance
Parties for any Losses under or in connection with any Finance Document which directly or
indirectly result from loss of or damage to the Vessel or a liability of the Vessel or the Owner,
being a loss or damage which is prima facie covered by an Obligatory Insurance but in respect of
which there is a non-payment (or reduced payment) by the underwriters by reason of, or on the basis
of any allegation concerning:






	 	(i)	 	any act or omission on the part of the Owner, of any operator or manager of the Vessel or of
any officer, employee or agent of the Owner or of any such person, including any breach of warranty
or condition or any non-disclosure relating to such Obligatory Insurance;





84









 





	 	(ii)	 	any act or omission, whether deliberate, negligent or accidental, or any knowledge or
privity of the Owner or any other person referred to in subparagraph (i) above, or of any officer,
employee or agent of an Owner or of such a person, including the casting away or damaging of the
Vessel and/or the Vessel being unseaworthy; and/or
	 
	 	(iii)	 	any other matter capable of being insured against under a mortgagee’s interest marine
insurance policy whether or not similar to the foregoing; and






	 	(b)	 	a mortgagee’s interest additional perils policy providing for the indemnification of the
Finance Parties against, amongst other things, any Losses or other consequences of any
Environmental Claim, including the risk of expropriation, arrest or any form of detention of the
Vessel, or the imposition of any Security Interest over the Vessel
and/or any other matter capable
of being insured against under a mortgagee’s interest additional perils (pollution) policy whether
or not similar to the foregoing.






	17.3	 	Obligatory Insurances
	 
	 	 	Without prejudice to its obligations under Clause 17.1 (Scope of Obligatory Insurances), the Owner
shall:






	 	(a)	 	not without the prior consent of the Facility Agent (acting on the instructions of the Majority
Lenders) alter any Obligatory Insurance nor make, do, consent or agree to any act or omission which
would or might render any Obligatory Insurance invalid, void, voidable or unenforceable or render
any sum paid out under any Obligatory Insurance repayable in whole or in part;
	 
	 	(b)	 	not cause or permit the Vessel to be operated in any way inconsistent with the provisions or
warranties of, or implied in, or outside the cover provided by, any Obligatory Insurance or to be
engaged in any voyage or to carry any cargo not permitted by any Obligatory Insurances;
	 
	 	(c)	 	duly and punctually pay all premiums, calls, contributions or other sums of money from time to
time payable in respect of any Obligatory Insurance;
	 
	 	(d)	 	at least 28 days before the relevant policies, contracts or entries expire, notify the Facility
Agent of the names of the insurance companies and/or the war risks and protection and indemnity
associations proposed to be employed for the purposes of the renewal of such Obligatory Insurances
and of the amounts in which such Obligatory Insurances are proposed to be renewed and the risks to
be covered, and to procure that appropriate instructions for the renewal of such Obligatory
Insurances on the terms so specified are given to the brokers (if applicable) and associations in
each case approved in accordance with Clause 17.1 (Scope of Obligatory Insurances) and will at
least three Business Days before such expiry (or within such shorter period as the Facility Agent
may from time to time agree) confirm in writing to the Facility Agent that such renewals have been
effected in accordance with the instructions so given;
	 
	 	(e)	 	forthwith upon the effecting of any Obligatory Insurance, ensure that all approved brokers (if
applicable) and/or approved insurers and the approved P&I Club provide the Facility Agent with pro
forma copies of all policies relating to the Obligatory Insurances which they are to effect or
renew and of a letter or letters of undertaking substantially in the forms scheduled to or referred
to in the Delivery General Assignment or such other form acceptable to the Facility Agent, in each
case stating the full particulars (including the dates and amounts) of the insurance, and on
request produce the receipts for each sum paid by it pursuant to




85









 






	 	 	 	paragraph (c) above, and including undertakings from the approved brokers (if applicable) or the
approved underwriters or insurance companies that:






	 	(i)	 	they will have endorsed on each policy, when issued, a loss payee provision and notice of
assignment, in the form scheduled to the Delivery General Assignment;
	 
	 	(ii)	 	they will hold such policies, and the benefit of such insurances, to the order of the Security
Trustee;
	 
	 	(iii)	 	they will advise the Facility Agent forthwith of any material change to the terms of the
Obligatory Insurances;
	 
	 	(iv)	 	they will upon written application by the approved brokers (if applicable) to the Facility
Agent notify the Facility Agent, not less than 28 days before the expiry of the Obligatory
Insurances, in the event of their not having received notice of renewal instructions from the Owner
or its agents and, in the event of their receiving instructions to renew, they will promptly notify
the Facility Agent of the terms of the instructions;
	 
	 	(v)	 	they will not exercise any rights of cancellation in respect of default in payment of premiums
without giving the Facility Agent 28 days’ notice in writing, either by letter or electronically
transmitted message, and a reasonable opportunity for the Facility Agent to pay any premiums
outstanding;
	 
	 	(vi)	 	if any of the Obligatory Insurances form part of a fleet cover, their lien on the fleet
policies shall be confined to the outstanding premiums due on the Vessel only;
	 
	 	(vii)	 	they shall neither set off against any claim(s) and/or returns of premium(s) in respect of
the Vessel any premiums due in respect of other vessels under the fleet cover or any premiums due
for other insurances, nor cancel the insurance for reason of non-payment of premiums for other
vessels under the fleet cover or of premiums for such other insurances; and
	 
	 	(viii)	 	they will arrange for a separate policy to be issued in respect of the Vessel forthwith upon
being so requested by the Facility Agent;






	 	(f)	 	not settle, release, compromise or abandon any claim in respect of any Total Loss unless the
Facility Agent (acting promptly and on the instructions of the Majority Lenders, acting reasonably)
is satisfied that such release, settlement, compromise or abandonment will not prejudice the
interests of the Finance Parties under or in relation to any Finance Document;
	 
	 	(g)	 	arrange for the execution and delivery of such guarantees as may from time to time be required
by any protection and indemnity or war risks club or association in accordance with the rules of
such club or association;
	 
	 	(h)	 	procure that the interest of the Security Trustee as mortgagee or assignee is noted on all
policies of insurance; and
	 
	 	(i)	 	in the event that the Owner receives payment of any moneys under the Delivery General
Assignment in respect of Insurances, save as provided in the loss payable clauses scheduled to the
Delivery General
Assignment, forthwith pay over the same to the Security Trustee and, until paid over, such moneys
shall be held in trust for the Security Trustee by the Owner.




86









 












	17.4	 	Power of Facility Agent to insure
	 
	 	 	If the Owner fails to effect and keep in force Obligatory Insurances in accordance with this
Agreement, it shall be permissible, but not obligatory, for the Facility Agent to effect and keep
in force insurance or insurances, for itself or on behalf of the Security Trustee, in the amounts
required under this Agreement and (in the case of Clause 17.1(d) (Scope of Obligatory Insurances)
only) entries in a protection and indemnity association or club and, if it deems necessary or
expedient, to insure the war risks upon the Vessel, and the Owner shall reimburse the Facility
Agent for the costs of so doing. The Facility Agent agrees to notify the Owner if it effects any
such insurance or insurances in respect of the Vessel as soon as practicable and in any event no
later than five Business Days after effecting such insurances.
	 
	18.	 	DEFAULT
	 
	18.1	 	Events of Default






	 	Each of the events or circumstances set out in this Clause 18 is an Event of Default, provided
always that:






	 
	 	(a)	 	the events referred to in Clauses 18.6 to 18.11 shall not, in respect of the Builder,
constitute an Event of Default if:






	 	(i)	 	the relevant event is remedied to the satisfaction of the Facility Agent (acting on the
instructions of the Majority Lenders) and on terms (and with replacement security) approved by the
Facility Agent (acting on the Instructions of the Majority Lenders); or
	 
	 	(ii)	 	the Builder is substituted by another builder satisfactory to the Facility Agent (acting on
the instructions of the Majority Lenders) and on terms (and with replacement security) approved by
the Facility Agent (acting on the Instructions of the Majority
Lenders), in each case by a date that falls three (3) months after the occurrence of the relevant event; and
	 








	 	(b)	 	the events referred to in Clauses 18.6 to 18.11 shall not, in respect of the Charterer or
Manager, constitute an Event of Default if a substitute charterer or substitute manager is
appointed, or the relevant event is otherwise cured by the Owner, in accordance with Clause 16.23.






	18.2	 	Non-payment
	 
	 	 	The Owner, Ocean Rig or the Sponsor does not pay on the due date any amount payable by it under the
Finance Documents in the manner required under the Finance Documents,
unless the non-payment:






	 	(a)	 	is caused by technical or administrative error; and
	 
	 	(b)	 	where such payment is a scheduled payment, is remedied within one Business Day of the due date;
or
	 
	 	(c)	 	where such payment is on-demand, is remedied within three Business Days of the date of demand.




87









 












	18.3	 	Breach of other obligations
	 
	 	 	The Owner, Ocean Rig or the Sponsor does not comply with any other terms of the Finance Documents
to which it is a party or the Sponsor does not comply with any of its obligations under the Finance
Documents to which it is a party, unless the non-compliance:






	 	(a)	 	is capable of remedy; and
	 
	 	(b)	 	is remedied within 30 days of the earlier of the Facility Agent giving notice of the breach to
the Owner and the Owner or the Sponsor, as the case may be, becoming aware of the noncompliance,
save in the case of non-compliance with:






	 	(i)	 	Clause 16.11(a) (Security), Clause 16.12(a) (Registration of the Vessel), Clause 16.22(c)
(Charters), Clause 16.24 (Management Agreement) (save to the extent Clause 16.23 (Breach or
Termination of Drilling Charter or Management Agreement) applies) or Clause 17.1 (Scope of
Obligatory Insurances), for each of which the grace period for remedy shall be three days from the
date the Facility Agent gives notice of the breach to the Owner, provided always that, in respect
of Clause 17.1 (Scope of Obligatory Insurances), clause 7.14 (Financial Covenants) of the Sponsor
Construction and Post-Delivery Guarantee and clause 7.14 (Financial Covenants) of the Ocean Rig
Guarantee, there shall be no grace period unless the Facility Agent (acting on the good faith and
reasonable instructions of the Majority Lenders) is satisfied that the Finance Parties have neither
suffered nor will, in the future, suffer any material detriment (whether financial, to their
security position or otherwise howsoever) as a result of the non-compliance; or
	 
	 	(ii)	 	Clause 16.23 (Breach or Termination of Drilling Charter or Management Agreement) for which
there shall be no grace period for remedy following expiry of the grace period provided in that
Clause 16.23.






	18.4	 	Misrepresentation
	 
	 	 	A representation or warranty made or repeated by the Owner, Ocean Rig or the Sponsor in any Finance
Document or in any document delivered by or on behalf of the Owner, Ocean Rig or the Sponsor under
any Finance Document is incorrect or misleading in any material respect when made or deemed to be
repeated, unless the circumstances giving rise to the misrepresentation or breach of warranty:






	 	(a)	 	are capable of remedy; and
	 
	 	(b)	 	are remedied within 14 days of the Owner, Ocean Rig or, as the case may be, the Sponsor
receiving notice from the Facility Agent of the circumstances giving rise to the misrepresentation
or breach of warranty.






	18.5	 	Cross-default






	 	(a)	 	Any Sister Event of Default occurs and is continuing; or
	 
	 	(b)	 	Any of the following occurs in respect of any of the Project Parties:






	 	(i)	 	any of its Financial Indebtedness is not paid when due (after the expiry of any originally
applicable grace period);




88









 












	 	(ii)	 	any of its Financial Indebtedness:






	 	(A)	 	becomes prematurely due and payable;
	 
	 	(B)	 	is placed on demand; or
	 
	 	(C)	 	is capable of being declared by or on behalf of a creditor to be prematurely due and payable or
of being placed on demand,






	 	 	 	in each case, as a result of an event of default or any provision having a similar effect
(howsoever described) and after the expiry of any applicable grace period (if any); or
	 
	 	(iii)	 	any commitment for its Financial Indebtedness is cancelled or suspended as a result of an
event of default (howsoever described),






	 	 	 	unless the aggregate amount of Financial Indebtedness falling within paragraphs (i) to (iii) above
is less than US$2,500,000 or its equivalent in the case of the Owner, Ocean Rig or the Sponsor or
US$10,000,000 or its equivalent in the case of, the Builder, the Charterer Parent (if any) or the
Charterer.






	18.6	 	Insolvency
	 
	 	 	Any of the following occurs in respect of any of the Project Parties:






	 	(a)	 	it is, or is deemed for the purposes of any relevant applicable law to be, unable to pay its
debts as they fall due or insolvent;
	 
	 	(b)	 	it admits its inability to pay its debts as they fall due;
	 
	 	(c)	 	it suspends making payments on any of its debts or announces an intention to do so;
	 
	 	(d)	 	by reason of actual or anticipated financial difficulties, it begins negotiations with any
creditor for the rescheduling or restructuring of any of its indebtedness;
	 
	 	(e)	 	the value of its assets is less than its liabilities (taking into account contingent and
prospective liabilities); or
	 
	 	(f)	 	a moratorium is declared in respect of any of its Financial Indebtedness; or
	 
	 	(g)	 	any similar local law process not described in (a) to (f) above.






	 	 	If a moratorium occurs in respect of any such person, the ending of the moratorium will not remedy
any Event of Default caused by the moratorium.
	 
	18.7	 	Insolvency proceedings






	 	(a)	 	Except as provided in paragraph (b) below, any of the following occurs in respect of any of the
Project Parties:






	 	(i)	 	any step is taken with a view to a moratorium, composition, assignment or similar arrangement
with any of its creditors;




89









 












	 	(ii)	 	a meeting of its shareholders, directors or other officers is convened for the purpose of
considering any resolution to petition for or to file documents with a court or any registrar for
its winding-up, administration or dissolution or any such resolution is passed;
	 
	 	(iii)	 	any person presents a petition or files documents with a court for its winding-up,
administration or dissolution or reorganisation (by way of voluntary arrangement, scheme of
arrangement or otherwise);
	 
	 	(iv)	 	any Security Interest is enforced over any of its assets;
	 
	 	(v)	 	an order for its winding-up, administration or dissolution is made;
	 
	 	(vi)	 	any liquidator, trustee in bankruptcy, judicial custodian, compulsory manager, receiver,
administrative receiver, receiver and manager, judicial manager, administrator or similar officer
is appointed in respect of it or any of its assets;
	 
	 	(vii)	 	its directors, shareholders or other officers request the appointment of, or give notice of
their intention to appoint a liquidator, trustee in bankruptcy, judicial custodian, judicial
manager, receiver and manager, compulsory manager, receiver, administrative receiver, receiver and
manager, administrator or similar officer; or
	 
	 	(viii)	 	any other analogous step or procedure is taken in any jurisdiction.






	 	(b)	 	Paragraph (a) above does not apply to a frivolous or vexatious petition for winding-up
presented by a creditor which is being contested in good faith and with due diligence and is
discharged or struck out within 14 days.






	 	18.8	 	Creditors’ process
	 
	 	 	 	Any attachment, sequestration, distress, execution or analogous event affects any asset(s) of any
of the Project Parties having an aggregate value of at least US$2,500,000 or its equivalent in the
case of the Owner, Ocean Rig or the Sponsor or at least US$10,000,000 or its equivalent in the case
of the Builder, Charterer Parent or the Charterer and in any case is not discharged within 14 days.
	 
	 	18.9	 	Cessation of business
	 
	 	 	 	Any of the Project Parties ceases, or threatens to cease, to carry on business.
	 
	 	18.10	 	Failure to pay final judgment
	 
	 	 	 	Any of the Project Parties fails to comply with or pay any sum in excess of US$2,500,000 or its
equivalent in the case of the Owner, Ocean Rig or the Sponsor or at least US$10,000,000 or its
equivalent in the case of the Builder, Charterer Parent (if any) or the Charterer and in either
case due from it under any final judgment or any final order made or given by any court of
competent jurisdiction within the period specified in the relevant judgment or if no period is
specified within 14 days of such final judgment being issued.
	 
	 	18.11	 	Material adverse change
	 
	 	 	 	Any event or series of events occurs affecting the financial condition or operation of any of the
Project Parties which, in the opinion of the Majority Lenders, has a Material Adverse Effect.




90









 






	 	18.12	 	Litigation
	 
	 	 	 	Any litigation, arbitration or administrative proceedings (other than proceedings of a frivolous or
vexatious nature which are being contested in good faith and for which adequate reserves or
security are at the relevant time maintained or provided or for which indemnity or liability
insurance cover for at least the full amount in dispute has been obtained by the Owner or the
relevant person from underwriters or insurance companies that have been approved by the Facility
Agent (acting on the instructions of the Majority Lenders acting reasonably)) are current or, to
the knowledge of the Owner or the Finance Parties, pending or threatened against any person which
in the opinion of the Majority Lenders have, or if adversely determined are reasonably likely to
have, a Material Adverse Effect.
	 
	 	18.13	 	Liability of Lenders and Administrative Parties






	 	(a)	 	Any event occurs or circumstance arises in relation to the Vessel which results in any person
making an Environmental Claim against any Finance Party and such Finance Party has not been
indemnified by a person and on terms satisfactory to the relevant Finance Party in respect of such
amount within fifteen days after the date on which such Environmental Claim is made provided such
Finance Party gives prompt notice of such claim to the Owner and has afforded the Owner (at its
cost and expense) the right (with full cooperation of such Finance Party) to such action as it
considers necessary or appropriate (acting reasonably) to defend or contest in its own name the
validity or amount of such claim. The Owner may defend or contest the validity or amount of such
claim in the name of the relevant Finance Party if such Finance Party is (acting in its absolute
discretion) satisfied that:






	 	(i)	 	such action has a reasonable chance of success and in reaching this conclusion such Finance
Party shall have the right to require the Owner to obtain (at the cost of the Owner) the opinion of
Queen’s Counsel concerning the merits of the claim. Counsel shall be selected and instructed by the
legal advisers to the Finance Party concerned;
	 
	 	(ii)	 	such Finance Party is satisfied that such claim will not materially damage its reputation or
any part of its business affairs; and
	 
	 	(iii)	 	the scope of the provisions of Clause 23.2 (Other indemnities) will indemnify the relevant
Finance Party against any and all costs, losses, expenses or liabilities arising as a result of the
Owner defending or contesting the validity or amount of the claim in the name of that Finance
Party.






	 	(b)	 	Any event occurs or circumstance arises in relation to the ownership or operation of the Vessel
which results in criminal liability being imposed on any Finance Party except where such liability
arises out of the gross negligence or wilful misconduct of such Finance Party.






	18.14	 	Unlawful performance
	 
	 	 	It is, or it becomes, unlawful for the Owner, Ocean Rig or the Sponsor to perform any of its
obligations under the terms of the Transaction Documents.
	 
	18.15	 	Debt Service Cover Ratio
	 
	 	 	The Debt Service Cover Ratio is determined to be less than 1.1:1 for any Calculation Period.




91









 












	18.16	 	Acceleration






	 	(a)	 	If an Event of Default is outstanding, the Facility Agent may (and if the Majority Lenders so
instruct it, shall), by notice to the Owner:






	 	(i)	 	cancel the undrawn, uncancelled amount of the Commitments;
and/or
	 
	 	(ii)	 	declare that all or part of any amounts outstanding under the Finance Documents are:






	 	(A)	 	immediately due and payable; and/or
	 
	 	(B)	 	payable on demand by the Facility Agent.






	 	 	 	Any notice given under this Clause 18.16 will take effect in accordance with its terms.
	 
	 	(b)	 	The Owner hereby agrees that for the purposes of this Agreement service by the Facility Agent
of a notice under and in accordance with paragraph (a) above shall constitute a valid and effective
service of such notice and the Owner shall be deemed to have become liable to make any payments
expressed in that notice upon service of such notice.






	19.	 	SECURITY
	 
	19.1	 	General
	 
	 	 	The provisions of clause 2 and clause 3 of the DPP apply in respect of the appointment, office and
function of the Security Trustee.
	 
	19.2	 	Parallel Debt






	 	(a)	 	For the purposes of the Greek Security, the Owner hereby irrevocably and unconditionally
undertakes to pay to the Security Trustee amounts equal to any amounts owing by the Owner to the
relevant Secured Parties under the Finance Documents as and when the same fall due for payment
thereunder, so that the Security Trustee shall be the obligee of such covenant to pay and shall be
entitled to claim performance thereof in its own name and not as agent acting on behalf of the
relevant Secured Parties. The Owner and the Security Trustee acknowledge that for this purpose such
obligations of the Owner are several and are separate and independent from, and without prejudice
to, the identical obligations which the Owner has to the Secured Parties under the relevant Finance
Documents, provided that this shall not result in the Owner incurring an aggregate obligation to
any such Secured Parties under the Finance Documents. To this end and without prejudice to the
foregoing, it is agreed that:






	 	(i)	 	the amounts due and payable by the Owner under this Clause 19.2 (the Parallel Debt) shall be
decreased to the extent that the Owner has paid any amounts to the Secured Parties or any of them
in respect of the Secured Liabilities and vice versa; and
	 
	 	(ii)	 	the Parallel Debt shall not exceed the aggregate of the corresponding obligations which the
Owner has to the Secured Parties under the Finance Documents.






	 	(b)	 	Nothing in this Clause shall in any way negate, affect or increase the obligations of the Owner
to any Secured Party under the Finance Documents in respect of the Secured Liabilities. For the
purpose of this Clause, the Security Trustee acts in its own name and on




92









 






	 	 	 	behalf of itself and not as agent or representative of any other party hereto and any security
granted to the Security Trustee to secure the Parallel Debt is granted to the Security Trustee in
its capacity as creditor of the Parallel Debt and solely for the purpose referred to above.






	19.3	 	Greek Security






	 	(a)	 	The Security Trustee shall obtain any Security Interest provided under or pursuant to a
Security Document governed by Greek law (the Greek Security) in its own name.
	 
	 	(b)	 	The Security Trustee shall have full and unrestricted entitlement to and authority in respect
of the Greek Security, provided that it shall be under an obligation to exercise such rights (and
perform such obligations) in accordance with the contractual undertakings set out in any Finance
Document.






	20.	 	THE ADMINISTRATIVE PARTIES
	 
	20.1	 	Appointment and duties of the Facility Agent






	 	(a)	 	Each Lender and Administrative Party (other than the Facility Agent) irrevocably appoints the
Facility Agent to act as its agent under and in connection with the Finance Documents.
	 
	 	(b)	 	Each Lender and Administrative Party irrevocably authorises the Facility Agent to:






	 	(i)	 	perform the duties and to exercise the rights, powers and discretions that are specifically
given to it under the Finance Documents, together with any other incidental rights, powers and
discretions; and
	 
	 	(ii)	 	execute each Finance Document expressed to be executed by the Facility Agent.






	 	(c)	 	The Facility Agent has only those duties which are expressly specified in the Finance
Documents. Those duties are solely of a mechanical and administrative nature. For the avoidance of
doubt, those duties do not extend to any administration or other work which might result from any
Lender transferring any of its rights and obligations under the Finance Documents to any person.
Any such administration or other work shall be undertaken by the transferee.






	20.2	 	Role of the Mandated Lead Arranger
	 
	 	 	Except as specifically provided in the Finance Documents, the Mandated Lead Arranger has no
obligations of any kind to any other Party in connection with any Finance Document.
	 
	20.3	 	No fiduciary duties
	 
	 	 	Except as specifically provided in a Finance Document, nothing in the Finance Documents makes an
Administrative Party a trustee or fiduciary for any other Party or any other person, and no
Administrative Party needs to hold in trust any moneys paid to or recovered by it for a Party in
connection with the Finance Documents or be liable to account for interest on those moneys.
	 
	20.4	 	Individual position of an Administrative Party






	 	(a)	 	If it is also a Lender, each Administrative Party has the same rights and powers under the
Finance Documents as any other Lender and may exercise those rights and powers as though it were
not an Administrative Party.




93









 






	 	(b)	 	Each Administrative Party may:






	 	(i)	 	carry on any business with the Owner, the Sponsor, the Charterer or the Sponsor or its related
entities (including acting as an agent or a trustee for any other financing); and
	 
	 	(ii)	 	retain any profits or remuneration it receives under the Finance Documents or in relation to
any other business it carries on with the Owner or its related entities.






	20.5	 	Reliance
	 
	 	 	The Facility Agent may:






	 	(a)	 	rely on any notice or document believed by it to be genuine and correct and to have been signed
by, or with the authority of, the proper person;
	 
	 	(b)	 	rely on any statement made by any person regarding any matters which may reasonably be assumed
to be within its knowledge or within its power to verify;
	 
	 	(c)	 	engage, pay for and rely on professional advisers selected by it; and
	 
	 	(d)	 	act under the Finance Documents through its personnel and agents.






	20.6	 	Majority Lenders’ instructions






	 	(a)	 	The Facility Agent is fully protected if it acts on the valid instructions of the Majority
Lenders in the exercise of any right, power or discretion or any matter not expressly provided for
in the Finance Documents. Any such instructions given by the Majority Lenders will be binding on
all the Lenders. In the absence of instructions, unless the Finance Documents expressly provide
that the Facility Agent acts on the instructions of the Majority Lenders or all of the Lenders in
exercising the relevant right, power or discretion, the Facility Agent may act or refrain from
acting as it considers to be in the best interests of all the Lenders.
	 
	 	(b)	 	The Facility Agent may assume that unless it has received notice to the contrary, any right,
power, authority or discretion vested in any Party or the Majority Lenders has not been exercised.
	 
	 	(c)	 	The Facility Agent may require the receipt of security satisfactory to it, whether by way of
payment in advance or otherwise, against any liability or loss which it may incur in complying with
the instructions of the Majority Lenders and may refrain from acting in accordance with the
instructions of the Majority Lenders (or, if appropriate, the Lenders) until it has received
security satisfactory to it, whether by way of payment in advance or otherwise, against any
liability or loss which it may incur in complying with the instructions.
	 
	 	(d)	 	The Facility Agent is not authorised to act on behalf of a Lender (without first obtaining that
Lender’s consent) in any legal or arbitration proceedings in connection with any Finance Document.






	20.7	 	Responsibility






	 	(a)	 	No Administrative Party is responsible to any other Finance Party for the adequacy, accuracy or
completeness of any Finance Document or any other document or any statement





94









 











		 	or information (whether written or oral) made or supplied in connection with any Finance Document.






	 	(b)	 	No Administrative Party is responsible for the legality, validity, effectiveness, adequacy,
completeness or enforceability of any Finance Document or any other document.
	 
	 	(c)	 	Without affecting the responsibility of the Owner for information supplied by it or on its
behalf in connection with any Finance Document, each Lender confirms that it:






	 	(i)	 	has made, and will continue to make, its own independent appraisal of all risks arising under
or in connection with the Finance Documents (including the financial condition and affairs of the
Owner, Ocean Rig, the Sponsor, the Charterer or the Sponsor and its related entities and the nature
and extent of any recourse against any Party, Ocean Rig, the Sponsor, the Charterer or the Sponsor
or its assets); and
	 
	 	(ii)	 	has not relied exclusively on any information provided to it by any Administrative Party in
connection with any Finance Document.






	20.8	 	Exclusion of liability






	 	(a)	 	The Facility Agent is not liable or responsible to any other Lender or Administrative Party for
any action taken or not taken by it in connection with any Finance Document, unless directly caused
by its gross negligence or wilful misconduct.
	 
	 	(b)	 	No Party (other than the relevant Administrative Party) may take any proceedings against any
officers, employees or agents of another Administrative Party in respect of any claim it might have
against that Administrative Party or in respect of any act or omission of any kind by that officer,
employee or agent in connection with any Finance Document. Any officer, employee or agent of an
Administrative Party may rely on this Clause 20.8 and enforce its terms under the Contracts (Rights
of Third Parties) Act 1999.
	 
	 	(c)	 	The Facility Agent is not liable for any delay (or any related consequences) in crediting an
account with an amount required under the Finance Documents to be paid by the Facility Agent if the
Facility Agent has taken all necessary steps as soon as reasonably practicable to comply with the
regulations or operating procedures of any recognised clearing or settlement system used by the
Facility Agent for that purpose.
	 
	 	(d)	 	Nothing in this Agreement will oblige any Administrative Party to satisfy any know your
customer requirement in relation to the identity of any person on behalf of any Finance Party.
	 
	 	(e)	 	Each Finance Party confirms to each Administrative Party that it is solely responsible for any
know your customer requirements it is required to carry out and that it may not rely on any
statement in relation to those requirements made by any other person.






	20.9	 	Default






	 	(a)	 	The Facility Agent is not obliged to monitor or enquire whether a Default has occurred. The
Facility Agent is not deemed to have knowledge of the occurrence of a Default.
	 
	 	(b)	 	If the Facility Agent:




95









 












	 	(i)	 	receives notice from a Party or any other party to a Transaction Document referring to
this Agreement, describing a Default and stating that the event is a Default; or
	 
	 	(ii)	 	is aware of the non-payment of any principal or interest or any fee payable to a Finance Party
(other than the Facility Agent or any of the Mandated Lead Arranger) under this Agreement,






	 	 	it must promptly notify the Finance Parties.
	 
	20.10	 	Information






	 	(a)	 	The Facility Agent must promptly forward to the person concerned the original or a copy of any
document which is delivered to the Facility Agent by a Party for that person.
	 
	 	(b)	 	Except where a Finance Document specifically provides otherwise, the Facility Agent is not
obliged to review or check the adequacy, accuracy or completeness of any document it forwards to
another Party.
	 
	 	(c)	 	Except as provided above, the Facility Agent has no duty:






	 	(i)	 	either initially or on a continuing basis to provide any Lender with any credit or other
information concerning the risks arising under or in connection with the Finance Documents
(including any information relating to the financial condition or affairs of the Owner or any of
its related entities or the nature or extent of recourse against any Party or its assets) whether
coming into its possession before, on or after the date of this Agreement; or
	 
	 	(ii)	 	unless specifically requested to do so by a Lender in accordance with a Finance Document, to
request any certificate or other document from the Owner.






	 	(d)	 	In acting as the Facility Agent, the agency division of the Facility Agent is treated as a
separate entity from its other divisions and departments. Any information acquired by the Facility
Agent which, in its opinion, is acquired by it otherwise than in its capacity as the Facility Agent
may be treated as confidential by the Facility Agent and will not be treated as information
possessed by the Facility Agent in its capacity as such.
	 
	 	(e)	 	The Owner irrevocably authorises the Facility Agent to disclose to the other Finance Parties
any information which is received by it in its capacity as the Facility Agent, subject always to
the requirements of confidentiality under Clause 28 (Disclosure of Information).
	 
	 	(f)	 	The Facility Agent is not obliged to disclose to any person any confidential information
supplied to it by or on behalf of the Owner solely for the purpose of evaluating whether any waiver
or amendment is required in respect of any term of the Finance Documents.






	20.11	 	Indemnities






	 	(a)	 	Without limiting the liability of the Owner under the Finance Documents, each Lender shall
indemnify the Facility Agent for that Lender’s Pro Rata Share of any loss or liability incurred by
the Facility Agent in acting as the Facility Agent (including without limitation any costs
associated with effecting, maintaining or renewing any insurances in accordance with and subject to
Clause 17.4 (Power of Facility Agent to insure) and acting in
accordance with the instructions of the Majority Lenders in accordance with Clause 20.6 (Majority
Lenders’ instructions)) unless the Facility Agent has been reimbursed by the Owner under a Finance




96









 






	 	 	 	Document, except to the extent that the loss or liability is caused by the Facility Agent’s gross
negligence or wilful misconduct.






	 	(b)	 	If a Party owes an amount to the Facility Agent under the Finance Documents, the Facility Agent
may after giving notice to that Party:






	 	(i)	 	deduct from any amount received by it for that Party any amount due to the Facility Agent from
that Party under a Finance Document but unpaid; and
	 
	 	(ii)	 	apply that amount in or towards satisfaction of the owed amount.






	 	 	That Party will be regarded as having received the amount so deducted.
	 
	20.12	 	Compliance
	 
	 	 	Each Administrative Party may refrain from doing anything (including disclosing any information)
which might, in its opinion, constitute a breach of any law or regulation or be otherwise
actionable at the suit of any person, and may do anything which, in its opinion, is necessary or
desirable to comply with any law or regulation.
	 
	20.13	 	Resignation of the Facility Agent






	 	(a)	 	The Facility Agent may resign and appoint any of its Affiliates as successor Facility Agent by
giving 30 days’ notice to the other Finance Parties and the Owner.
	 
	 	(b)	 	Alternatively the Facility Agent may resign by giving written notice to the Finance Parties and
the Owner, in which case the Majority Lenders may appoint a successor Facility Agent.
	 
	 	(c)	 	If no successor Facility Agent has been appointed under paragraph (b) above within 30 days
after notice of resignation was given, the Facility Agent may appoint a successor Facility Agent.
	 
	 	(d)	 	The resignation of the Facility Agent and the appointment of any successor Facility Agent will
both become effective only when the successor Facility Agent (i) notifies all the Parties that it
accepts its appointment and (ii) confirms that it is satisfied that the rights under the Security
Documents and the DPP have been assigned or transferred to it. On giving the notification and
confirmation, the successor Facility Agent will succeed to the position of the Facility Agent and
the term Facility Agent will mean the successor Facility Agent.
	 
	 	(e)	 	The retiring Facility Agent must, at its own cost, make available to the successor Facility
Agent such documents and records and provide such assistance as the successor Facility Agent may
reasonably request for the purposes of performing its functions as the Facility Agent under the
Finance Documents. 
	 
	 	(f)	 	Upon its resignation becoming effective, this Clause will continue to benefit
the retiring Facility Agent in respect of any action taken or not taken by it in connection with
the Finance Documents while it was the Facility Agent, and, subject to paragraph (e) above, it will
have no further obligations in its capacity as Facility Agent under any Finance Document.
	 
	 	(g)	 	The Majority Lenders may, by notice to the Facility Agent, require it to resign under paragraph
(b) above.




97









 












	 	(h)	 	Any successor Facility Agent will be located or have a branch in London, Luxembourg or New
York and the Facility Agent or, as the case may be, the Mandated Lead Arranger will consult with
the Owner in relation to the identity of such successor Facility Agent.






	20.14	 	Relationship with Lenders






	 	(a)	 	The Facility Agent may treat each Lender as a Lender, entitled to payments under this Agreement
and as acting through its Facility Office(s) unless it has received not less than five Business
Days prior notice in writing from that Lender to the contrary.
	 
	 	(b)	 	The Facility Agent may at any time, and must if requested to do so by the Majority Lenders,
convene a meeting of the Lenders.
	 
	 	(c)	 	The Facility Agent must keep a record of all the Parties and supply any other Party with a copy
of the record on request. The record will include each Lender’s Facility Office(s) and contact
details for the purposes of this Agreement.






	20.15	 	Notice period
	 
	 	 	Where this Agreement specifies a minimum period of notice to be given to the Facility Agent, the
Facility Agent may, at its discretion, accept a shorter notice period.
	 
	21.	 	EVIDENCE AND CALCULATIONS
	 
	21.1	 	Accounts
	 
	 	 	Accounts maintained by the Facility Agent in connection with this Agreement are conclusive (save
for manifest error) evidence of the matters to which they relate for the purpose of any litigation
or arbitration proceedings.
	 
	21.2	 	Certificates and determinations
	 
	 	 	Any certification or determination by a Finance Party of a rate or amount under the Finance
Documents will be, in the absence of manifest error, conclusive evidence of the matters to which it
relates.
	 
	21.3	 	Calculations
	 
	 	 	Any interest or fee accruing under this Agreement accrues from day to day and is calculated on the
basis of Clause 7.1(d) being the actual number of days elapsed and a year of 360 days or otherwise,
depending on what the Facility Agent determines is market practice.
	 
	22.	 	FEES
	 
	22.1	 	Commitment fee






	 	(a)	 	The Owner shall pay to the Facility Agent for the account of each Lender a fee calculated at
the rate of sixty basis points (60bps) per annum on the undrawn, uncancelled amount of the Maximum
Facility Amount at such time.
	 
	 	(b)	 	The accrued commitment fee is payable to the Facility Agent quarterly in arrear on the last day
of each Term, the first payment to be paid on the last day of the first Term. Accrued commitment
fee is also payable to the Facility Agent for a Lender on the date that Lender’s Commitment is
cancelled or drawn in full.




98









 












	22.2	 	Agency and Security Trustee fee
	 
	 	 	The Owner must pay to the Administrative Parties for their respective own account an agency and
security trustee fee in the amount and manner agreed in the Fee Letter between the Administrative
Parties and the Owner.
	 
	22.3	 	Refund of fees
	 
	 	 	The fees referred to in this Clause 22 shall not be refunded under any circumstances whatsoever
once they have been paid.
	 
	23.	 	INDEMNITIES AND BREAK COSTS
	 
	23.1	 	Currency indemnity






	 	(a)	 	The Owner shall, as an independent obligation, indemnify each Secured Party against any cost,
loss or liability which that Secured Party or any of its Affiliates incurs as a consequence of:






	 	(i)	 	the Secured Party receiving an amount in respect of the Owner’s liability under the Finance
Documents; or
	 
	 	(ii)	 	that liability being converted into a claim, proof judgment or order,
in a currency other than the currency in which the amount is expressed to be payable under the
relevant Finance Document.






	 	(b)	 	Unless otherwise required by law, the Owner waives any right it may have in any jurisdiction to
pay any amount under the Finance Documents in a currency other than that in which it is expressed
to be payable.






	23.2	 	Other indemnities






	 	(a)	 	The Owner shall, as an independent obligation, indemnify each Secured Party and any Affiliate
against any cost, loss or liability which that Secured Party or any of its Affiliates incurs as a
consequence of:






	 	(i)	 	the occurrence of any Event of Default;
	 
	 	(ii)	 	any failure by the Owner to pay any amount due under a Finance Document on its due date
including any resulting from any distribution or redistribution of any amount among the Lenders
under this Agreement;
	 
	 	(iii)	 	(other than by reason of gross negligence or default by that Finance Party) a Loan not being
made after a Request has been delivered for that Loan; or
	 
	 	(iv)	 	a Loan (or part of a Loan) not being prepaid in accordance with this Agreement.






	 	 	The liability of the Owner in each case includes any cost, loss or expense on account of funds
borrowed, contracted for or utilised to fund any amount payable under any Finance Document.






	 
	 	(b)	 	The Owner must indemnify against any cost, loss or liability incurred by any Administrative
Party as a result of:




99









 












	 	(i)	 	investigating any event which that Administrative Party reasonably believes is a Default; or
	 
	 	(ii)	 	acting or relying on any notice which that Administrative Party reasonably believes to be
genuine, correct and appropriately authorised,






	 	 	 	(and any such Administrative Party with such a belief must promptly notify the Facility Agent of
the same).
	 
	 	(c)	 	The Owner must promptly pay and discharge, or cause to be paid or discharged, upon the same
becoming payable (and shall, if requested by a Secured Party, produce to that Secured Party
evidence of the payment and discharge thereof) and indemnify on demand and keep indemnified each
Secured Party and its Affiliates on a full indemnity basis against a claim against it by, or a
liability to, a third party including, without limitation, in relation to any Taxes (other than any
Taxes levied or assessed on net income, profits or gains) or any other Losses which relate to or
arise out of or are in any way connected to:






	 	(i)	 	the condition, testing, delivery, design, leasing, chartering, sub-chartering, construction,
manufacture, purchase, acquisition, bailment, fitting out, sale, importation to or exportation from
any country, registration, ownership, possession, management, control, inspection, surveying,
engineering, contracting, installation, manning, provisioning, the provision of bunkers and
lubricating oils, dry docking, use, operation, maintenance, repair, service, modification,
overhaul, replacement, removal, performance, transportation, flag, navigation, certification,
classification, nature, description, acceptance, insurance, refurbishment, conversion, change,
alteration or laying-up of the Vessel or any part thereof or otherwise in connection with the
Vessel including, without prejudice to the generality of the foregoing, any Losses arising from any
pollution or other environmental damage caused by or emanating from the Vessel or caused by the
Vessel becoming a wreck or an obstruction to navigation whether or not the Vessel (or any part
thereof) is in possession or control of the Owner or the Manager or any other person and wherever
the location;
	 
	 	(ii)	 	any repossession, return, redelivery, storage, maintenance, protection, attempted sale, sale
or other disposition of the Vessel following the termination of the chartering of the Vessel which,
if carried out by the Facility Agent, Security Trustee or the Lenders, is carried out in accordance
with the terms of the Finance Documents;
	 
	 	(iii)	 	the complete or partial removal, decommissioning, disposal, making safe, destruction,
abandonment or loss of the Vessel including any matter which the Vessel contains or has at any time
contained;
	 
	 	(iv)	 	any damage or loss to the Vessel irrespective of how caused;
	 
	 	(v)	 	any Environmental Claim or any actual or alleged breach, contravention or violation of any
Environmental Laws or Environmental Approvals in any way relating to the Vessel or the activities
of any Environmental Affiliates;
	 
	 	(vi)	 	any design, article or material of the Vessel or relating thereto giving rise to any
infringement (or alleged infringement) of any patent or other intellectual property rights; or




100









 












	 	(vii)	 	the occupation, arrest, confiscation, requisition, theft, registration, compulsory
acquisition, restraint of the Vessel or prevention thereof seizure, taking in execution,
impounding, forfeiture or detention of the Vessel, or in securing the release of the Vessel
(including, without limitation, by the provision of or by procuring a guarantee, bond, cash deposit
or other like security).






	23.3	 	Exclusions from Indemnities
	 
	 	 	The indemnities contained in this Clause 23 shall not extend to any claim or liability of a Secured
Party or its Affiliates to the extent that such claim or liability:






	 	(a)	 	arises from an act or omission on the part of that Secured Party or, as the case may be
Affiliate which constitutes fraud, wilful misconduct or gross negligence on the part of such
Secured Party or, as the case may be, Affiliate;
	 
	 	(b)	 	is caused by any failure on the part of that Secured Party to comply with any of its express
obligations under any of the Finance Documents to which that Secured Party is a party (but
excluding any such breach or failure that arises as a result of the failure of a party to such
Finance Document (other than that Secured Party) duly and punctually to perform its express
obligations);
	 
	 	(c)	 	is one in respect of which that Secured Party or, as the case may be, Affiliate, is expressly
and specifically indemnified and has received and is entitled to retain such indemnity under any
other provision of the Finance Documents; or
	 
	 	(d)	 	is a cost or expense expressly borne by the Secured Parties under any Finance Document.






	23.4	 	Break Costs






	 	(a)	 	The Owner must pay to each Lender or, as the case may be, each Swap Bank, its Break Costs in
accordance with this Agreement.
	 
	 	(b)	 	Break Costs are, subject to paragraphs (c) and (d), the amount (if any) determined by the
relevant Lender by which:






	 	(i)	 	the interest which that Lender would have received for the period from the date of receipt of
payment of any part of its share in a Loan or an overdue amount to the last day of the applicable
Term for that Loan or overdue amount if the principal or overdue amount received had been paid on
the last day of that Term;
	 
	 	 	 	exceeds
	 
	 	(ii)	 	the amount which that Lender would be able to obtain by placing an amount equal to the
principal amount or overdue amount received by it on deposit with a leading bank in the London
interbank market for a period starting on the Business Day following receipt and ending on the last
day of the applicable Term.






	 	(c)	 	In respect of an Eksportfinans Lender, Break Costs means the amount (if any) determined by that
Eksportfinans Lender by which:






	 	(i)	 	the net present value of the interest which the Eksportfinans Lender should have received by
applying the Eksportfinans CIRR on the Eksportfinans Loan for the period starting on the date of
receipt of the Eksportfinans Loan or its relevant part




101









 






	 	 	 	thereof to (and including) the Final Maturity Date (such amount to be calculated to take into
account all of the Repayment Dates in accordance with the Repayment Schedule, as if the
Eksportfinans Loan or its relevant part thereof had been repaid on all of the scheduled Instalment
Repayment Dates to and including the Final Maturity Date),
	 
	 	 	 	exceeds
	 
	 	(ii)	 	the net present value of the amount that Eksportfinans Lender would be able to obtain by
placing an amount equal to the Eksportfinans Loan or its relevant part thereof at the Prepayment
Swap Rate for the period starting on the Business Day following receipt of the Eksportfinans Loan
or its relevant part thereof to (and including) the Final Maturity Date and following the Repayment
Schedule.






	 	 	 	For the purposes of this paragraph (c), Prepayment Swap Rate means the rate quoted on the Bloomberg
Screen IRSB US page for a period starting on the Business Day following receipt of the
Eksportfinans Loan or that Eksportfinans Lender’s relevant part thereof and ending on the Final
Maturity Date (such amount to be calculated to take into account all of the Repayment Dates to and
including the Final Maturity Date.
	 
	 	(d)	 	In respect of a Swap Bank and a Swap Agreement, Break
Costs are the amount (if any) determined
by the relevant Swap Bank as being an amount equal to any Swap Termination Payment for that Swap
Agreement.
	 
	 	(e)	 	Each Lender or, as the case may be, each Swap Bank must supply to the Owner a certificate
showing the calculations in reasonable detail confirming the amount of any Break Costs claimed by
it under this Clause.






	24.	 	EXPENSES
	 
	24.1	 	Initial costs
	 
	 	 	The Owner must pay to each Secured Party the amount of all costs and expenses (including legal
fees, Technical Adviser’s fees, insurance, environmental and Tax consultants’ fees) incurred by it
in connection with the negotiation, syndication (including any assignment or transfer of
participation in any Loan or Commitment to a new lender for the purposes of syndication or
otherwise), negotiation, preparation, printing, entry into, perfection and preservation of the
Finance Documents and matters incidental thereto.
	 
	24.2	 	Subsequent costs
	 
	 	 	The Owner must pay to each Secured Party the amount of all costs and expenses (including legal
fees) incurred by it in connection with:






	 	(a)	 	the negotiation, preparation, printing and entry into of any Finance Document executed after
the date of this Agreement;
	 
	 	(b)	 	any amendment, waiver or consent requested by or on behalf of the Owner or specifically allowed
by this Agreement; and
	 
	 	(c)	 	the provision by the Technical Adviser of all reports, confirmations and advice provided by it
to the Finance Parties during the Pre-Delivery Period and on the Final Completion Date.




102









 












	24.3	 	Enforcement costs
	 
	 	 	Following an Event of Default, the Owner must pay to each Secured Party the amount of all costs and
expenses (including legal fees) incurred by it in connection with the enforcement or attempted
enforcement of, or the preservation or attempted preservation of any rights under, any Finance
Document.
	 
	25.	 	WAIVER OF CONSEQUENTIAL DAMAGES
	 
	 	 	In no event shall any Secured Party be liable on any basis of liability for any special, indirect,
consequential or punitive damages and the Owner hereby waives, releases and agrees (for itself and
on behalf of its Holding Companies) not to sue upon any such claim for any such damages, unless
caused by the fraud, gross negligence or wilful default of the relevant Secured Party in
performance of any of its obligations under this Agreement or any of the Finance Documents.
	 
	26.	 	AMENDMENTS AND WAIVERS
	 
	26.1	 	Procedure






	 	(a)	 	Except as provided in this Clause 26, no term of the Finance Documents may be amended or waived
without the agreement of the Owner and the Facility Agent. The Facility Agent (acting on the
instructions of the Majority Lenders, or otherwise in accordance with the relevant Finance
Documents) may effect, on behalf of any Finance Party, an amendment or waiver allowed under this
Clause.
	 
	 	(b)	 	The Facility Agent must promptly notify the other Parties and each Swap Bank of any amendment
or waiver effected by it under paragraph (a) above. Any such amendment or waiver is binding on all
the Parties.
	 
	 	(c)	 	The Owner shall not be concerned or have any responsibility to ensure that the Facility Agent
has received any necessary authorisation or consent from the Lenders, and may rely on the agreement
of the Facility Agent above.






	26.2	 	Exceptions






	 	(a)	 	An amendment or waiver which relates to:






	 	(i)	 	the definition of Majority Lenders in Clause 1.1 (Definitions);
	 
	 	(ii)	 	an extension of the date of payment of any amount to a Lender under the Finance Documents;
	 
	 	(iii)	 	a reduction in the amount of any payment of principal, interest, fee or other amount payable
to a Lender under the Finance Documents;
	 
	 	(iv)	 	an increase in, or an extension of, a Commitment or the Total Commitments;
	 
	 	(v)	 	a release of the Owner other than in accordance with the terms of this Agreement;
	 
	 	(vi)	 	a release of any Security Document other than in accordance with the terms of this Agreement;
	 
	 	(vii)	 	a term of a Finance Document which expressly requires the consent of each Lender;




103









 












	 	(viii)	 	the right of a Lender to assign or transfer its rights or obligations under the Finance
Documents;
	 
	 	(ix)	 	the ranking or subordination provided for in the DPP;
	 
	 	(x)	 	any assignment or transfer by the Owner pursuant to Clause 27.1 (Assignments and transfers by
the Owner);
	 
	 	(xi)	 	Clause 2.4 (Nature of a Finance Party’s rights and obligations); or
	 
	 	(xii)	 	this Clause,






	 	 	 	may only be made with the consent of all the Lenders. An amendment or waiver which relates to the
rights and/or obligations of an Administrative Party may only be made with the consent of that
Administrative Party.
	 
	 	(b)	 	An amendment or waiver which relates to a reduction in the Applicable Margin in respect of the
Eksportfinans Loans during the Pre-Completion Period or the Post-Completion Eksportfinans Interest
Rate may only be made with the consent of all the Eksportfinans Lenders and the Owner.
	 
	 	(c)	 	An amendment or waiver which relates to a reduction in LIBOR or the Applicable Margin in
respect of the KEXIM Loans may only be made with the consent of all the KEXIM Lenders and the
Owner.
	 
	 	(d)	 	An amendment or waiver which relates to a reduction in the Applicable Margin in respect of the
Commercial Loans may only be made with the consent of all the Commercial Lenders and the Owner.
	 
	 	(e)	 	A Fee Letter may be amended or waived with the agreement of each Administrative Party or, as
the case may be, Mandated Lead Arranger that is party to that Fee Letter and the Owner.






	26.3	 	Change of currency
	 
	 	 	If a change in any currency of a country occurs (including where there is more than one currency or
currency unit recognised at the same time as the lawful currency of a country), the Finance
Documents will be amended to the extent the Facility Agent (acting reasonably and on the
instructions of the Majority Lenders and after consultation with the Owner) determines is necessary
to reflect the change.
	 
	26.4	 	Waivers and remedies cumulative
	 
	 	 	The rights of each Secured Party under the Finance Documents:






	 	(a)	 	may be exercised as often as necessary;
	 
	 	(b)	 	are cumulative and not exclusive of its rights under the general law; and
	 
	 	(c)	 	may be waived only in writing and specifically.






	 	 	Delay in exercising or non-exercise of any right is not a waiver of that right.




104









 












	27.	 	CHANGES TO THE PARTIES
	 
	27.1	 	Assignments and transfers by the Owner
	 
	 	 	The Owner may not assign or transfer any its rights and obligations under the Finance Documents
without the prior consent of the Facility Agent (acting on the instructions of all of the Lenders).
	 
	27.2	 	Assignments and transfers by Lenders






	 	(a)	 	Subject to Clause 27.5 but without further cost to the Owner, a Lender (the Existing Lender)
may at any time assign or transfer (including by way of novation) any of its rights and obligations
under this Agreement to any other bank or other financial institution or other entity which is
regularly engaged in or established for the purpose of making, issuing, purchasing or investing in
loans, securities and other financial assets (the New Lender).
	 
	 	(b)	 	Any Eksportfinans Lender may at any time assign or transfer (including by way of novation) any
of its rights and obligations under this Agreement to GIEK.
	 
	 	(c)	 	The Facility Agent is not obliged to execute a Transfer Certificate until it has completed all
know your customer requirements to its satisfaction. The Facility Agent must promptly notify the
Existing Lender and the New Lender if there are any such requirements.
	 
	 	(d)	 	A transfer of obligations will be effective only if the obligations are novated in accordance
with the following provisions of this Clause 27.
	 
	 	(e)	 	On the transfer becoming effective in this manner, the relevant Lender will be released from
its obligations under this Agreement to the extent that they are transferred to the New Lender.
	 
	 	(f)	 	Any reference in the Finance Documents to a Lender includes a New Lender but excludes a Lender
if no amount is or may be owed to or by it under the Finance Documents.
	 
	 	(g)	 	The New Lender shall pay a transfer fee of US$5,000 to the Facility Agent immediately following
any transfer under and in accordance with the provisions of this Clause 27.
	 
	 	(h)	 	Each Lender agrees not to effect any assignment or transfer under this Clause 27 without
simultaneously effecting a pro rata assignment or transfer of its
equivalent rights and/or
obligations under the Sister Loan Agreement.






	27.3	 	Procedure for transfer by way of novations






	 	(a)	 	In this Clause 27.3:
	 
	 	 	 	Transfer Date means, for a Transfer Certificate, the later of:






	 	(i)	 	the proposed transfer Date specified in that transfer Certificate; and
	 
	 	(ii)	 	the date on which the Facility Agent executes that Transfer Certificate.






	 	(b)	 	A novation is effected if:






	 	(i)	 	the Existing Lender and the New Lender deliver to the Facility Agent a duly completed Transfer
Certificate; and




105











 












	 	(ii)	 	the Facility Agent executes it.






	 	(c)	 	On the Transfer Date:






	 	(i)	 	the New Lender will assume the rights and obligations of the Existing Lender expressed to be
the subject of the novation in the Transfer Certificate in substitution for the Lender; and
	 
	 	(ii)	 	the Existing Lender will be released from those obligations and cease to have those rights.






	 	(d)	 	Each Party (other than the Existing Lender and the New Lender) irrevocably authorises the
Facility Agent to execute any duly completed Transfer Certificate on its behalf.
	 
	 	(e)	 	The Facility Agent must, as soon as reasonably practicable after it has executed a Transfer
Certificate, send to the Owner a copy of that Transfer Certificate.






	27.4	 	Limitation of responsibility of Existing Lender






	 	(a)	 	Unless expressly agreed to the contrary, an Existing Lender makes no representation or warranty
and assumes no responsibility to a New Lender for:






	 	(i)	 	the financial condition of the Owner or any other Project Party; or
	 
	 	(ii)	 	the legality, validity, effectiveness, completeness, accuracy, adequacy, enforceability or
performance of:






	 	(A)	 	any Finance Document or any other document;
	 
	 	(B)	 	any statement or information (whether written or oral) made in or supplied in connection with
any Finance Document; or
	 
	 	(C)	 	any observance by the Owner, Ocean Rig or the Sponsor of its obligations under any Finance
Document or any other documents,






	 	 	and any representations or warranties implied by law are excluded.






	 	(b)	 	Each New Lender confirms to the Existing Lender that it:






	 	(i)	 	has made, and will continue to make, its own independent appraisal of all risks arising under
or in connection with the Finance Documents (including the financial condition and affairs of the
Owner and its related entities, or any other Project Party and the nature and extent of any
recourse against any Party or any other Project Party or its or their assets) in connection with
its participation in this Agreement; and
	 
	 	(ii)	 	has not relied exclusively on any information supplied to it by the Existing Lender in
connection with any Finance Document.






	 	(c)	 	Nothing in any Finance Document requires an Existing Lender to:






	 	(i)	 	accept a re-transfer from a New Lender of any of the rights and obligations assigned or
transferred under this Clause 27; or




106









 












	 	(ii)	 	support any losses incurred by the New Lender by reason of the non-performance by the
Owner of its obligations under any Finance Document or otherwise.






	27.5	 	Costs resulting from change of Lender or Facility Office
	 
	 	 	If:






	 	(a)	 	a Lender assigns or transfers any of its rights and obligations under the Finance Documents or
changes its Facility Office; and
	 
	 	(b)	 	as a result of circumstances existing at the date of the assignment, transfer or change occurs,
the Owner would be obliged to pay a Tax Payment or an Increased Cost,






	 	 	then, unless the assignment, transfer or change is made by a Lender to mitigate any circumstances
giving rise to a Tax Payment, Increased Cost or a right to be prepaid
and/or cancelled by reason of
illegality, the Owner need only pay that Tax Payment or Increased Cost to the same extent that it
would have been obliged to if no assignment, transfer or change had occurred.
	 
	27.6	 	Changes to the Reference Banks
	 
	 	 	If a Reference Bank (or, if a Reference Bank is not a Lender, the Lender of which it is an
Affiliate) ceases to be a Lender, the Facility Agent must (in consultation with the Owner) appoint
another Lender or an Affiliate of a Lender to replace that Reference Bank in consultation with the
Owner.
	 
	28.	 	DISCLOSURE OF INFORMATION






	 	(a)	 	Each Finance Party must keep confidential any information supplied to it by or on behalf of the
Owner in connection with the Finance Documents. However, a Finance Party is entitled to disclose
information:






	 	(i)	 	which is publicly available, other than as a result of a breach by that Finance Party of this
Clause 28;
	 
	 	(ii)	 	in connection with any legal or arbitration proceedings;
	 
	 	(iii)	 	if required to do so under any Applicable Law;
	 
	 	(iv)	 	to a governmental, banking, taxation or other regulatory authority;
	 
	 	(v)	 	to its professional advisers;
	 
	 	(vi)	 	to the extent allowed under paragraph (b) below; or
	 
	 	(vii)	 	with the agreement of the Owner.






	 	(b)	 	A Finance Party may disclose to an Affiliate or any person with whom it may enter, or has
entered into, any kind of transfer, participation or other agreement in relation to this Agreement
(a participant):






	 	(i)	 	a copy of any Finance Document; and
	 
	 	(ii)	 	any information which that Finance Party has acquired under or in connection with any Finance
Document.





107









 





	 	 	 	However, before a participant may receive any confidential information, it must agree with the
relevant Finance Party (for the benefit of each Finance Party and the Owner) to keep that
information confidential on the terms of paragraph (a) above.






	 	(c)	 	This Clause 28 supersedes any previous confidentiality undertaking given by a Finance Party in
connection with this Agreement prior to it becoming a Party.






	29.	 	SET-OFF
	 
	 	 	A Finance Party may set off any matured obligation owed to it by the Owner under the Finance
Documents against any obligation (whether or not matured) owed by that Finance Party to the Owner,
regardless of the place of payment, booking branch or currency of either obligation. If the
obligations are in different currencies, that Finance Party may convert either obligation at a
market rate of exchange in its usual course of business for the purpose of the set-off.
	 
	30.	 	PRO RATA SHARING
	 
	30.1	 	Redistribution
	 
	 	 	If any amount owing by the Owner under this Agreement to a Finance Party (the recovering Finance
Party) is discharged by payment, set-off or any other manner other than through the Facility Agent
under this Agreement (a recovery), then:






	 	(a)	 	the recovering Finance Party must, within three Business Days, supply details of the recovery
to the Facility Agent;
	 
	 	(b)	 	the Facility Agent must calculate whether the recovery is in excess of the amount which the
recovering Finance Party would have received if the recovery had been received by the Facility
Agent under this Agreement; and
	 
	 	(c)	 	the recovering Finance Party must pay to the Facility Agent an amount equal to such excess (the
redistribution).






	30.2	 	Effect of redistribution






	 	(a)	 	The Facility Agent must treat a redistribution as if it were a payment by the Owner under this
Agreement and distribute it among the Finance Parties, other than the recovering Finance Party,
accordingly.
	 
	 	(b)	 	When the Facility Agent makes a distribution under paragraph (a) above, the recovering Finance
Party will be subrogated to the rights of the Lenders which have shared in that redistribution.
	 
	 	(c)	 	If and to the extent that the recovering Finance Party is not able to rely on any rights of
subrogation under paragraph (b) above, the Owner will owe the recovering Finance Party a debt which
is equal to the redistribution, immediately payable and of the type originally discharged.
	 
	 	(d)	 	If:






	 	(i)	 	a recovering Finance Party must subsequently return a recovery, or an amount measured by
reference to a recovery, to the Owner; and




108









 












	 	(ii)	 	the recovering Finance Party has paid a redistribution in relation to that recovery,






	 	 	 	each Finance Party must reimburse the recovering Finance Party all or the appropriate portion of
the redistribution paid to that Finance Party, together with interest for the period while it held
the re-distribution. In this event, the subrogation in paragraph (b) above will operate in reverse
to the extent of the reimbursement.






	30.3	 	Exceptions
	 
	 	 	Notwithstanding any other term of this Clause 30, a recovering Finance Party need not pay a
redistribution to the extent that:






	 	(a)	 	it would not, after the payment, have a valid claim against the Owner in the amount of the
redistribution; or
	 
	 	(b)	 	it would be sharing with another Lender any amount which the recovering Finance Party has
received or recovered as a result of legal or arbitration proceedings, where:






	 	(i)	 	the recovering Finance Party notified the Facility Agent of those proceedings; and
	 
	 	(ii)	 	the other Finance Party had an opportunity to participate in those proceedings but did not do
so or did not take separate legal or arbitration proceedings as soon as reasonably practicable
after receiving notice of them.






	31.	 	SEVERABILITY
	 
	 	 	If a term of a Finance Document is or becomes illegal, invalid or unenforceable in any respect
under any jurisdiction, that will not affect:






	 	(a)	 	the legality, validity or enforceability in that jurisdiction of any other term of the Finance
Documents; or
	 
	 	(b)	 	the legality, validity or enforceability in other jurisdictions of that or any other term of
the Finance Documents.






	32.	 	COUNTERPARTS
	 
	 	 	Each Finance Document may be executed in any number of counterparts. This has the same effect as if
the signatures on the counterparts were on a single copy of the Finance Document.
	 
	33.	 	NOTICES
	 
	33.1	 	In writing






	 	(a)	 	Any communication in connection with a Finance Document must be in writing and, unless
otherwise stated, may be given:






	 	(i)	 	in person, by post or fax; or






	 	(ii)	 	to the extent agreed by the Parties making and receiving the communication, by email or other
electronic communication.






	 	(b)	 	For the purpose of the Finance Documents, an electronic communication will be treated as being
in writing.




109









 












	 	(c)	 	Unless it is agreed to the contrary, any consent or agreement required under a Finance
Document must be given in writing.






	33.2	 	Contact details






	 	(a)	 	Except as provided below, the contact details of each Party for all communications in
connection with the Finance Documents are those notified by that Party for this purpose to the
Facility Agent on or before the date it becomes a Party.
	 
	 	(b)	 	The contact details of the Owner for this purpose are:






	 	Address: 	 	 c/o Dryships Inc.

80 Kifissias Avenue

GR-151 25 Amaroussion

Greece
	 
	 	Fax number: 	 	 +30 2108090275
	 	Attention: 	 	 Mr. Ziad Nakhleh, Chief Financial Officer






	 	(c)	 	The contact details of the Facility Agent for this purpose are:






	 	Address: 	 	 2, Boulevard Konrad Adenauer
	 	 	 	L- 1115 Luxembourg
	 
	 	Fax number: 	 	 +352 421 22659/552
	 	E-mail: 	 	 banu.ozkutan@db.com franz-josef.ewerhardydb.com
	 	Attention: 	 	 Banu Ozkutan
	 	 	 	Franz-Josef Ewerhardy, International Loans and Agency Services






	 	(d)	 	The contact details of the Security Trustee for this purpose are:






	 	Address: 	 	 c/o Deutsche Bank Luxembourg S.A.
	 	 	 	2, Boulevard Konrad Adenauer
	 	 	 	L- 1115 Luxembourg
	 
	 	Fax number: 	 	 +352 421 22659/552
	 	E-mail: 	 	 banu.ozkutan@db.com / franz-josef.ewerhardy@db.com
	 	Attention: 	 	 Banu Ozkutan /
	 	 	 	Franz-Josef Ewerhardy, International Loans and Agency Services






	 	(e)	 	A Party may change its contact details by giving five Business Days’ notice to the Facility
Agent or (in the case of the Facility Agent) to the other Parties.
	 
	 	(f)	 	Where a Party nominates a particular department or officer to receive a communication, a
communication will not be effective if it fails to specify that department or officer.






	33.3	 	Effectiveness






	 	(a)	 	Except as provided below, any communication in connection with a Finance Document will be
deemed to be given as follows:






	 	(i)	 	if delivered in person, at the time of delivery;




110









 












	 	(ii)	 	if posted, five days after being deposited in the post, postage prepaid, in a correctly
addressed envelope; and
	 
	 	(iii)	 	if by fax, when received in legible form.






	 	(b)	 	A communication given under paragraph (a) above but received on a non-working day or after
business hours in the place of receipt will only be deemed to be given on the next working day in
that place.
	 
	 	(c)	 	A communication to the Facility Agent will only be effective on actual receipt by it.






	33.4	 	The Owner
	 
	 	 	All communications under the Finance Documents to or from the Owner must be sent through the
Facility Agent.
	 
	33.5	 	Entire Agreement
	 
	 	 	This Agreement and the other Finance Documents entered into pursuant to this Agreement contain the
whole agreement between the parties relating to the transactions contemplated by this Agreement and
supersede all previous agreements between the parties relating to such transactions.
	 
	34.	 	LANGUAGE






	 	(a)	 	Any notice given in connection with a Finance Document must be in English.
	 
	 	(b)	 	Any other document provided in connection with a Finance Document must be:






	 	(i)	 	in English; or
	 
	 	(ii)	 	(unless the Facility Agent otherwise agrees) accompanied by a certified English translation.
In this case, the English translation prevails unless the document is a statutory or other official
document.






	35.	 	GOVERNING LAW
	 
	 	 	This Agreement and any non-contractual obligations arising out of or in connection with it, are
governed by and shall be construed in accordance with English law.
	 
	36.	 	ENFORCEMENT
	 
	36.1	 	Jurisdiction






	 	(a)	 	The English courts have jurisdiction to settle any dispute in connection with any Finance
Document or any non-contractual obligations in connection with them, and the parties irrevocably
submit to the jurisdiction of the Courts of England and Wales, including in connection with any
dispute relating to any non-contractual obligations arising out of or in connection with any
Finance Document.
	 
	 	(b)	 	The English courts are the most appropriate and convenient courts to settle any such dispute in
connection with any Finance Document. The Owner agrees not to argue to the contrary and waives
objection to those courts on the grounds of inconvenient forum or otherwise in relation to
proceedings in connection with any Finance Document.




111









 












	 	(c)	 	This Clause 36 is for the benefit of the Lenders and the Administrative Parties only. To
the extent allowed by law, the Lenders and the Administrative Parties may take:






	 	(i)	 	proceedings in any other court; and
	 
	 	(ii)	 	concurrent proceedings in any number ofjurisdictions.






	 	(d)	 	References in this Clause to a dispute in connection with a Finance Document include any
dispute as to the existence, validity or termination of that Finance Document.






	36.2	 	Service of process






	 	(a)	 	The Owner irrevocably appoints Ince Process Agents Ltd of International House, 5th Floor, 1st
Katherine’s Way, London, E1W lAY (attn: Mr. Michael Volikas) as its agent under the Finance
Documents for service of process in any proceedings before the English courts in connection with
any Finance Document.
	 
	 	(b)	 	If any person appointed as process agent under this Clause is unable for any reason to act as
agent for service of process, the Owner must forthwith (and in any event within five (5) days of
the event taking place) appoint another agent on terms acceptable to the Facility Agent (acting
reasonably). Failing this, the Facility Agent may appoint another process agent for this purpose.
	 
	 	(c)	 	The Owner agrees that failure by a process agent to notify it of any process will not
invalidate the relevant proceedings.
	 
	 	(d)	 	This Clause 36 does not affect any other method of service allowed by law.






	36.3	 	Waiver of immunity
	 
	 	 	The Owner irrevocably and unconditionally:






	 	(a)	 	agrees not to claim any immunity from proceedings brought by a Finance Party against it in
relation to a Finance Document and to ensure that no such claim is made on its behalf
	 
	 	(b)	 	consents generally to the giving of any relief or the issue of any process in connection with
those proceedings; and
	 
	 	(c)	 	waives all rights of immunity in respect of it or its assets.




THIS AGREEMENT has been entered into on the date stated at the beginning of this Agreement.





112











 





SCHEDULE 1




ORIGINAL LENDERS



	 	 	 	 	 	 	 	 	 	 	 	 	 
	 	 	Commitments	 
	 	 	Eksportfinans	 	 	KEXIM	 	 	Commercial	 
	Name of Original Lender	 	Commitments (US$)	 	 	Commitments (US$)	 	 	Commitments (US$)	 
	Eksportfinans Lenders:
	 	 	 	 	 	 	 	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	Eksportfinans ASA
	 	 	250,000,000	 	 	 	 	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	KEXIM Lenders
	 	 	 	 	 	 	 	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	Export — Import Bank of Korea
	 	 	 	 	 	 	150,000,000	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	Deutsche Bank AG, London Branch
	 	 	 	 	 	 	12,500,000	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	Commercial Lenders:
	 	 	 	 	 	 	 	 	 	 	 	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	Deutsche Bank AG, London Branch
	 	 	 	 	 	 	 	 	 	 	25,000,000	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	DVB Bank N.V., Nordic Branch
	 	 	 	 	 	 	 	 	 	 	30,000,000	 
	 
	 	 	 	 	 	 	 	 	 	 	 	 
	Helaba Landesbank Hessen-Thüringen
Girozentrale, New
York Branch
	 	 	 	 	 	 	 	 	 	 	27,500,000	 






113









 






SCHEDULE 2




CONDITIONS PRECEDENT



PART 1



INCIDENTAL COSTS LOAN




	1.	 	An up to date certificate of good standing of the Owner, the Parent, the Parent Shareholder and the
Sponsor dated no more than two Business Days prior to the first Utilisation Date and a certified
copy of the certificate of incorporation and constitutional documents of each.
	 
	2.	 	A certified copy of a resolution of the board of directors of the Owner, the Parent, the Parent
Shareholder and the Sponsor:






	 	(a)	 	approving the terms of, and the transactions contemplated by, each Finance Document to which it
is a party and resolving that it executes each such Finance Document then to be executed;
	 
	 	(b)	 	authorising a specified person or persons to execute each Finance Document on its behalf to
which it is a party, then to be executed; and
	 
	 	(c)	 	authorising a specified person or persons, on its behalf, to sign and/or despatch all other
documents and notices to be signed and/or despatched by it under or in connection with each Finance
Document then to be executed.






	3.	 	A specimen of the signature of each person authorised by the resolutions referred to in 2 above.
	 
	4.	 	An original of each of the following documents, notarised, legalised and/or apostilled as
necessary, duly executed by the parties to it:






	 	(a)	 	each Finance Document (save for those Finance Documents listed in paragraph 8 of Part 2 of this
Schedule, paragraph 9 of Part 3 of this Schedule and in paragraphs 2 and 13 of Part 5 of this
Schedule) including each Swap Agreement.
	 
	 	(b)	 	each Sister Finance Document (save for those Sister Finance Documents listed in paragraph
8 of schedule 2, part 2 of the Sister Loan Agreement, paragraph 9 of schedule 2, part 3 of the
Sister Loan Agreement and paragraphs 2 and 13 of schedule 2, part 5 of the Sister Loan
Agreement);
	 
	 	(c)	 	the GIEK Guarantee issued in favour of the Eksportfinans Lenders; and
	 
	 	(d)	 	any mandate or similar document, to be entered into by the Owner with the Account Bank.






	5.	 	A certified copy of each Related Contract (other than any Drilling Charter, Charterer Parent
Guarantee, the Management Agreement and Obligatory Insurances).
	 
	6.	 	Duly executed originals (or, if originals are not available, fax pdf copies with originals to
follow as soon as possible and in any event within five (5) Business Days) of all notices of
assignment required to be served under each Security Document and duly executed originals (or, if
originals are not available, fax/pdf copies with originals to follow as soon as possible and in any
event within one (1) month) of the acknowledgements thereof (but not including the notices and
acknowledgements to




114









 












	 	 	be served under the Charter Assignment or the Delivery General Assignment), notarised, legalised
and/or apostilled, as required.
	 
	7.	 	A letter from Ince Process Agents Ltd., agreeing to its appointment as process agent for the
Owner and the Sponsor under the Finance Documents.
	 
	8.	 	A legal opinion of Allen & Overy LLP, London, English legal advisers to the Lenders, addressed
to the Facility Agent as agent for and on behalf of itself and the Lenders.
	 
	9.	 	A legal opinion of Woo, Yun, Kang, Jeong Han, Korean legal advisers to the Lenders, addressed to
the Facility Agent as agent for and on behalf of itself and the Lenders.
	 
	10.	 	A legal opinion of Seward & Kissel LLP, Marshall Islands legal advisers to the Lenders,
addressed to the Facility Agent as agent for and on behalf of itself and the Lenders.
	 
	11.	 	A legal opinion of Pologiorgis, Babalis, Panselinos, Troullinos, Mavrou Law Offices, Greek
legal advisers to the Lenders, addressed to the Facility Agent as agent for and on behalf of itself
and the Lenders.
	 
	12.	 	Evidence that all fees (including all fees payable on or at the first Utilisation Date under
the Fee Letters and legal costs) and reasonable out-of-pocket expenses then due and payable from
the Owner under the Finance Documents have been or will be paid by the first Utilisation Date or
other drawdown as part of the Incidental Costs Loan.
	 
	13.	 	Evidence that each Account has been opened in accordance with the Finance Documents.
	 
	14.	 	Detailed construction, operating and maintenance cost budget, the total Vessel capex plan
including the construction schedule, and pro-forma financial projections prepared by the Owner with
respect to the project the subject of the Related Contracts in form and substance satisfactory to
the Lenders.
	 
	15.	 	Opinion and report by Marsh that all Construction Insurances are in acceptable form and amount
and placed with acceptable underwriters, and such opinion, report and insurance is acceptable to
the Facility Agent.
	 
	16.	 	Confirmation from the Builder that the Owner has paid it in aggregate an amount equal to at
least the Initial Equity Contribution and confirmation from the Account Bank or, as the case may
be, the Equity Account Bank that the Owner has paid:






	 	(a)	 	any Balancing Equity Contribution into the Proceeds Account; and
	 
	 	(b)	 	the Equity Collateral to be paid under the terms of this Agreement on or by the Incidental
Costs Loan Utilisation Date into the Equity Account.






	17.	 	Certified copy of the Sponsor’s audited annual financial statements for the year ended 31
December
2007.
	 
	18.	 	Evidence that all Transaction Authorisations required by the Owner or Sponsor to perform its
obligations under the Transaction Documents have been obtained or will, at the appropriate time, be
obtained.
	 
	19.	 	Certificate from the Owner confirming that there are no material disputes with the Builder and
confirmation from the same that there have been no amendments or variations to the Shipbuilding




115









 












	 	 	Contract or the Other Shipbuilding Contract other than amendments disclosed and agreed in writing
prior to the date hereof or permitted under the terms of this Agreement.
	 
	20.	 	Confirmation from the Lenders that they have satisfied their “know your customer” requirements in
respect of the relevant parties to the Transaction Documents.
	 
	21.	 	Confirmation from the Sponsor that as far as it is aware there has been no material adverse
change in the prospects of the Owner or the operations or financial condition of the Owner, the
Manager (if an Affiliate of the Sponsor) or the Sponsor as from the date of this Agreement.
	 
	22.	 	A copy of any and all invoices issued by the Builder in relation to any Instalments payable by
the Owner on or before the Incidental Costs Loan Utilisation Date.
	 
	23.	 	Original Share Certificates of each of the Owner, the Parent and the Parent Shareholder in
relation to the Share Charge.
	 
	24.	 	Executed blank share transfer forms in relation to the Share Charge.
	 
	25.	 	Confirmation, if applicable, that in the circumstances referred to in Clause 18.1 (Events of
Default), following an event of insolvency in respect of the Builder, a replacement builder has
been agreed by the Finance Parties and the Owner within three months of the date of such insolvency
event.
	 
	26.	 	A legal opinion of Allen & Overy LLP, English legal advisers to GIEK, addressed to
Eksportfinans and concerning certain provisions of the GIEK Guarantee.
	 
	27.	 	Completion of each Lender’s legal, technical, environmental, financial, tax and insurance due
diligence with regard to the project, including, among others, review of all Related Contracts and
receipt of appropriate internal credit approvals by such Lender.
	 
	28.	 	Receipt by the Kexim Lenders of the Kexim Guarantee and evidence that any special conditions
required by Kexim in connection with the Facility have been met.
	 
	29.	 	A duly signed syndication letter between GIEK, Deutsche Bank AG, London Branch and Dexia Credit
Local, New York Branch.




In this Schedule 1 “certified copy” means a copy certified by an officer of the Owner as being
true, complete and up to date.








116









 








PART 2




INSTALMENT LOAN 1




	1.	 	Refresh certificates, update report or, as the case may be confirmation and satisfactory
evidence of continued compliance with the conditions precedent referred to in Part 1 of this
Schedule at paragraphs 1, 2, 3, 18, 19, and 21.
	 
	2.	 	Receipt of updated budgets and financial projections referred to in Part 1 of this Schedule at
paragraph 14.
	 
	3.	 	Confirmation from the Account Bank that the Owner has deposited in the Proceeds Account:






	 	(a)	 	any Balancing Equity Contribution; and
	 
	 	(b)	 	the relevant Equity Contribution required under Clause 12.2(a)(i)(B) in respect of the
Instalment Loan 1.






	4.	 	A certified copy of the invoice issued by the Builder in relation to the Instalment payable by
the Owner on the Instalment Loan 1 Utilisation Date.
	 
	5.	 	Confirmation, if applicable, that in the circumstances referred to in Clause 18.1 (Events of
Default), following an event of insolvency in respect of the Builder, a replacement builder has
been agreed by the Finance Parties and the Owner within three months of the date of such insolvency
event.
	 
	6.	 	Evidence from the Equity Account Bank that the sum of U.S.$90,000,000 has been placed in the
Equity Account in accordance with Clause 12.2(a)(iii)(B).
	 
	7.	 	A certified copy of the Management Agreement.
	 
	8.	 	An original of the Management Agreement Assignment, notarised, legalised and/or apostillised as
necessary, duly executed by the parties to it together with duly executed originals (or, if
originals are not available, fax/pdf copies with originals to follow as soon as possible and in any
event within five
(5) Business Days) of the notice of assignment to the Manager and a duly executed original (or, if
originals are not available, fax/pdf copies with originals to follows as soon as possible and in
any event within one (1) month) of the acknowledgement from the Manager, notarised, legalised and
or apostillised, as required.
	 
	9.	 	A legal opinion of Simonsen Advokatfirma, Norwegian legal advisers to the Lenders, addressed to
the Facility Agent as agent for and on behalf of itself and the Lenders.
	 
	10.	 	A legal opinion of Allen & Overy LLP, London, English legal advisers to the Lenders, addressed
to the Facility Agent as agent for and on behalf of itself and the Lenders.




117









 











PART 3




INSTALMENT LOAN 2




	1.	 	Refresh certificates or, as the case may be confirmation and satisfactory evidence of continued
compliance with the conditions precedent referred to in Part 1 of this Schedule at paragraphs 1, 2,
3, 18, 19,and 2l.
	 
	2.	 	Receipt of updated budgets and financial projections referred to in Part 1 of this Schedule at
paragraph 14, and certificate from the Classification Society verifying that the construction
milestones for the Instalment Loan 2 Utilisation Date specified under Clause 16.29 (Construction
Milestones) has been met.
	 
	3.	 	Confirmation from the Account Bank that the Owner has deposited in the Proceeds Account:






	 	(a)	 	any Balancing Equity Contribution; and
	 
	 	(b)	 	the relevant Equity Contribution required under Clause 12.2(a)(i)(B), in respect of the
Instalment Loan 2.






	4.	 	Confirmation, if applicable, that in the circumstances referred to in Clause 18.1 (Events of
Default), following an event of insolvency in respect of the Builder, a replacement builder has
been agreed by the Finance Parties and the Owner within three months of the date of such insolvency
event.
	 
	5.	 	A certified copy of the Petrobras Charter duly executed.
	 
	6.	 	A certified copy of the invoice issued by the Builder in relation to the Instalment payable by
the Owner on the Instalment Loan 2 Utilisation Date or, if the Instalment Loan is to be used to
refinance the Instalment, the invoice issued by the Builder in relation to the Instalment referred
to in Article II paragraph 4(c) of the Shipbuilding Contract together with evidence in writing that
the Owner has paid the relevant Instalment to the Builder.
	 
	7.	 	Evidence from the Equity Account Bank that the required Equity Collateral has been placed in the
Equity Account in accordance with Clause 12.2(a)(iii)(C).
	 
	8.	 	Evidence from the Account Bank that the amount of US$25,000,000 has been paid into the Debt
Service Reserve Account in accordance with Clause 12.8(a).




118









 











PART 4




INSTALMENT LOAN 3




	1.	 	Refresh certificates or, as the case may be confirmation and satisfactory evidence of continued
compliance with the conditions precedent referred to in Part 1 of this Schedule at paragraphs 1, 2,
3, 18, 19,and 2l.
	 
	2.	 	Receipt of updated budgets and financial projections referred to in Part 1 of this Schedule at
paragraph 14 and a certificate from the Classification Society verifying that the construction
milestones for the Instalment Loan 3 Utilisation Date specified under Clause 16.29 (Construction
Milestones) has been met.
	 
	3.	 	Confirmation from the Account Bank that the Owner has deposited in the Proceeds Account:






	 	(a)	 	any Balancing Equity Contribution; and
	 
	 	(b)	 	the relevant Equity Contribution required under Clause 12.2(a)(i)(B), in respect of the
Instalment Loan 3.






	4.	 	Confirmation, if applicable, that in the circumstances referred to in Clause 18.1 (Events of
Default), following an event of insolvency in respect of the Builder, a replacement builder has
been agreed by the Finance Parties and the Owner within three months of the date of such insolvency
event.
	 
	5.	 	A certified copy of the invoice issued by the Builder in relation to the Instalment payable by
the Owner on the Instalment Loan 3 Utilisation Date or, if the Instalment Loan is to be used to
refinance the Instalment, the invoice issued by the Builder in relation to the Instalment referred
to in Article II paragraph 4(d) of the Shipbuilding Contract together with evidence in writing that
the Owner has paid the relevant Instalment to the Builder.




119









 











PART 5




DELIVERY LOAN




	1.	 	A certified copy of the invoice issued by the Builder in relation to the Instalment payable by
the Owner on the Delivery Loan Utilisation Date.
	 
	2.	 	Evidence that the requirements and obligations under Clause 16.35 (Petrobras Charter) have, in
the opinion of the Facility Agent (acting on the instructions of all of the Lenders), been
satisfied.
	 
	3.	 	Duly executed originals (other than any bareboat charter agreement, a certified copy of which
shall be provided) of each of the documents required pursuant to Clause 16.35 (Petrobras Charter),
notarised, legalised and/or apostilled as necessary.
	 
	4.	 	A duly executed original of the Delivery General Assignment and the Mortgage.
	 
	5.	 	A duly executed Power of Attorney and the Appointment of Judicial Representative in respect of
the Mortgage.
	 
	6.	 	A legal opinion from Allen & Overy LLP, London, English legal advisers to the Lenders, in
respect of the Delivery General Assignment.
	 
	7.	 	A legal opinion from Seward & Kissel, Marshall Islands legal adviser to the Lenders, in respect
of the Delivery General Assignment and the Mortgage.
	 
	8.	 	A legal opinion of Tanzanian counsel approved by the Facility Agent in relation to Petrobras
Tanzania’s due execution of the Petrobras Charter.
	 
	9.	 	A transcript of the Marshall Islands Ship Registry showing that:






	 	(a)	 	the Mortgage has been duly recorded in the Marshall Islands and constitutes a first priority
security interest over the Vessel and that all taxes and fees payable to the Marshall Islands
Registrar of Shipping in respect of the Vessel have been paid in full; and
	 
	 	(b)	 	the Vessel is provisionally registered in the name of the Owner as a fully completed Marshall
Islands ship free of all Security Interests other than Permitted Liens.






	10.	 	Copies of such other documents and/or legal opinions which, based on legal advice received from
the relevant advisers referred to in this Agreement and which are reasonably required to evidence
the legality, validity and enforceability of the obligations of the parties to any Finance Document
or any of the documents required pursuant to Clause 16.35 (Petrobras Charter) being delivered on
the Delivery Loan Utilisation Date.
	 
	11.	 	A certified copy of:






	 	(a)	 	a final classification certificate from the Classification Society in respect of the Vessel
showing the Vessel to be in class without recommendation, condition or qualification (other than
any immaterial recommendations, conditions or qualifications that are capable of rectification
within 12 months or such shorter period as is required by the Classification Society) or, in the
event that this is not available, a faxed copy with a certified copy to follow as soon as
practicable after the Delivery Date;
	 
	 	(b)	 	a valid Interim Safety Management Certificate;




120









 












	 	(c)	 	a valid Document of Compliance; and
	 
	 	(d)	 	a valid International Ship Security Certificate.






	12.	 	Confirmation acceptable to the Facility Agent (such acceptance not to be unreasonably withheld
or delayed) that the Owner will accept the Vessel pursuant to the terms of the Shipbuilding
Contract and execute a protocol of delivery and acceptance.
	 
	13.	 	A certified copy of the commercial invoice in respect of the Vessel.
	 
	14.	 	A certified copy of the Builder’s certificate in respect of the Vessel.
	 
	15.	 	Duly executed and, where necessary, notarised, legalised and/or apostilled notices of
assignment of the Obligatory Insurances in respect of the Vessel duly executed by the Owner
substantially in the form provided for in the Delivery General Assignment and all confirmations and
acknowledgements required in accordance with the terms of the Delivery General Assignment.
	 
	16.	 	Confirmation from the Facility Agent of its satisfaction with a final insurance report prepared
by Marsh, or such other insurance adviser appointed by the Facility Agent and fax confirmations
from each broker (if applicable), insurer and club concerned with the Obligatory Insurances that
the insurances meet the requirements set out in Clause 17.1 including the insurances referred to in
Clause 17.1(e), will be effective from the actual delivery of the Vessel and are consistent with
the requirements of the Drilling Charter.
	 
	17.	 	Duly executed letters of undertaking substantially in the form provided in the Delivery General
Assignment from, inter alios, the approved brokers (if applicable), insurer and club concerned with
the Obligatory Insurances.
	 
	18.	 	The Annual Budget of the Owner in agreed form and approved by the Lenders, for the year from
the date of payment of the Delivery Loan falls.
	 
	19.	 	Confirmation from the Account Bank that the Owner has deposited in the Proceeds Account:






	 	(a)	 	any Balancing Equity Contribution required under Clause 12.2(a)(i); and
	 
	 	(b)	 	the relevant Equity Contribution required under Clause 12.2(a)(i)(B), in respect of the
Delivery Loan.






	20.	 	A copy of any and all invoices issued by the Builder in relation to any Instalments payable by
the Owner on or before the Delivery Loan Utilisation Date.
	 
	21.	 	Refresh certificates or, as the case may be confirmation and satisfactory evidence of continued
compliance with the conditions precedent referred to in Part 1 of this Schedule at paragraphs 1, 2,
3, 19, 20 and 22.
	 
	22.	 	Evidence that the Required DSRA Balance has been or will immediately after the drawing of the
Delivery Loan be credited to the balance of the Debt Service Reserve Account.
	 
	23.	 	Receipt of updated budgets and financial projections referred to in Part 1 of this Schedule at
paragraph 22, and a technical memorandum issued by the Technical Adviser covering the relevant
Workscope, to be achieved by the Delivery Loan Utilisation Date and confirming that the
construction milestones specified under Clause 16.29 (Construction Milestones) has been met.




121









 












	24.	 	Evidence that the Owner’s equity in the Vessel is not less than 30% of the total Vessel Cost.
	 
	25.	 	Evidence that the project the subject of the Related Contracts, has sufficient ongoing
maintenance opex and working capital requirements, and evidence in the form of reserves, if
necessary, that the Owner will be able to meet these ongoing requirements.
	 
	26.	 	Confirmation from the Owner and the Facility Agent (acting on behalf of each of the Lenders) of
their satisfactory due diligence on the Charterer’s and the Lenders’ withholding tax and the
Owner’s withholding tax and corporation tax exposure, if any.
	 
	27.	 	Provision of a tax opinion from the Owner’s tax advisers (which may be disclosed to the Finance
Parties) in respect of potential withholding and income tax payable under the Transaction Documents
in form and substance satisfactory to each of the Finance Parties.
	 
	28.	 	Confirmation, if applicable, that in the circumstances referred to in Clause 18.1 (Events of
Default), following an event of insolvency in respect of the Builder, a replacement builder has
been agreed by the Finance Parties and the Owner within three months of the date of such insolvency
event.




122









 











PART 6




INCIDENTAL VESSEL COSTS LOAN




	1.	 	A copy of any and all invoices in respect of approved Incidental Vessel Costs payable by the
Owner on or immediately following the proposed Utilisation Date for the requested Incidental Vessel
Costs Loan.
	 
	2.	 	Confirmation from the Account Bank that the Owner has deposited in the Proceeds Account:






	 	(a)	 	any Balancing Equity Contribution; and
	 
	 	(b)	 	the relevant Equity Contribution required under Clause 12.2(a)(i)(B), in respect of the
relevant Incidental Vessel Costs Loan.




123









 










SCHEDULE 3




FORM OF REQUEST


To:   Deutsche Bank Luxembourg S.A. as Facility Agent



From: Drillship Kithira Owners Inc.




Date: [                    ]




Credit Agreement dated [          ] 2008 (the Credit Agreement)





	1.	 	We refer to the Credit Agreement. This is a Request. Terms defined in the Credit Agreement shall
have the same meaning when used in this Request.
	 
	2.	 	We wish to borrow a Loan from you as follows:






	 	(a)	 	Utilisation Date: [      ]
	 
	 	(b)	 	Amount: US$[     ]
	 
	 	 	 	Incidental Costs Loan/Instalment Loan 1/Instalment Loan 2/Instalment Loan 3/Incidental Vessel Costs
Loan/Delivery Loan*
	 
	 	 	 	Amount payable to the Builder towards the Instalment under the Shipbuilding Contract:
US$[     ]
	 
	 	 	 	+[Amount payable to the Debt Service Reserve Account: US$[Required DSRA Balance]
	 
	 	 	 	[Amount payable in respect of Incidental Vessel Costs as set out below (as supported by the
relevant attached invoices):
	 
	 	 	 	[Amount payable in respect of Incidental Loan Costs as set out below:]
	 
	 	(c)	 	Details of item: US$[     ]
	 
	 	(d)	 	Details of item: US$[      ]]
	 
	 	 	 	Total drawdown: US$[     ]






	3.	 	Our payment instructions are:
	 
	 	 	[to include provisions that:






	 	(a)	 	amount of Loan in respect of Instalment payable under the Shipbuilding Contract to be payable
to the Builder’s account [set out account details];
	 
	 	(b)	 	[Required DSRA Balance to be credited to the Debt Service Reserve Account;
	 
	 	(c)	 	Incidental Loan Costs to be credited to the Facility Agent’s nominated account; and
	 
	 	(d)	 	Incidental Vessel Costs to be credited to [the Owner’s: current account for forward payment to]
the relevant payee account indicated in invoice]




124









 












	4.	 	We confirm that each condition precedent under the Credit Agreement which must be satisfied on
the date of this Request is so satisfied and that the Repeating Representation are true and correct
with reference to the facts and circumstances now subsisting.
	 
	5.	 	This Request is irrevocable.
	 
	6.	 	If applicable, a copy of:






	 	(a)	 	[the relevant invoice from the Builder the final stage certificate signed by the Builder and
us; and
	 
	 	(b)	 	the relevant invoices in respect of the Incidental Vessel Costs,






	 	 	is attached to this Request.]
	 
	By:	 	 DRILLSHIP KITHIRA OWNERS INC.




Authorised Signatory






 




			
	*	 	Delete as appropriate
	 
	+	 	Delivery Loan only




125









 










SCHEDULE 4




FORM OF TRANSFER CERTIFICATE


To:   DRILLSHIP KITHIRA OWNERS INC.



From: [THE EXISTING LENDER] and [THE NEW LENDER]




Date: [                    ]




Credit Agreement dated [                    ] (the Credit Agreement)



We refer to Clause 27.3 (Procedure for transfer by way of novations) of the Credit Agreement. Terms
defined in the Credit Agreement shall have the same meaning when used in this Novation Certificate.





	1.	 	We
[          
] (the Existing Lender) and
[           ] (the New Lender) agree to the Existing Lender and the New
Lender novating all the Existing Lender’s rights and obligations referred to in the Schedule in
accordance with Clause 27.3 (Procedure for transfer by way of novations) of the Credit Agreement.
	 
	2.	 	The specified date for the purposes of Clause 27.3(a) of the Credit Agreement is [date of novation].
	 
	3.	 	The Facility Office and address for notices of the New Lender for the purposes of Clause 33.2
(Contact details) of the Credit Agreement are set out in the Schedule attached to this Certificate.
	 
	4.	 	This Novation Certificate is governed by English law.




126









 











THE SCHEDULE



Rights and obligations to be novated



[Choose either of the following options:]





	(a)	 	All of the rights and obligations of the Existing Lender in respect of the Facility — principal
amount US$[          ].
	 
	(b)	 	The principal amount of US$[          ] in respect of each of the Loans and all the rights and
obligations
attached to the same — total principal amount US$[          ].




[New Bank]



[Facility Office Address for notices]




	 	 	 

	[Existing Lender]

	 	[New Lender]
	 
	 	 
	By:

	 	By:
	 
	 	 
	Date:

	 	Date:





The Transfer Date is confirmed by the Facility Agent as [          ].



[                    ]



By:





127









 








SCHEDULE 5




LOAN REPAYMENT SCHEDULE



	 	 	 	 	 
	 	 	Date	 	Repayment
	1

	 	30 March 2012
	 	US$27,500,000
	2

	 	28 September 2012
	 	US$27,500,000
	3

	 	28 March 2013
	 	US$27,500,000
	4

	 	30 September 2013
	 	US$27,500,000
	5

	 	31 March 2014
	 	US$27,500,000
	6

	 	30 September 2014
	 	US$27,500,000
	7

	 	31 March 2015
	 	US$27,500,000
	8

	 	30 September 2015
	 	US$27,500,000
	9

	 	31 March 2016
	 	US$27,500,000
	10

	 	30 September 2016
	 	US$27,500,000
	11

	 	31 March 2017
	 	US$27,500,000
	12

	 	29 September 2017
	 	US$27,500,000
	13

	 	29 March 2018
	 	US$27,500,000
	14

	 	29 September 2018
	 	US$27,500,000
	15

	 	29 March 20l9
	 	US$27,500,000
	16

	 	30 September 2019
	 	US$27,500,000
	17

	 	31 March 2020
	 	US$27,500,000
	18

	 	30 September 2020
	 	US$27,500,000






128









 






SCHEDULE 6




CALCULATION CERTIFICATE


To:   Deutsche Bank Luxembourg S.A as Facility Agent



From: Drillship Kithira Owners Inc.




Driliship Kithira Owners Inc. Credit Agreement dated [                     ] (the Credit Agreement)





	1.	 	Terms defined in the Credit Agreement have the same meaning in this Certificate.
	 
	2.	 	We hereby certify that [no Default or Mandatory Termination Event has occurred and is continuing
or is outstanding] [a Default/Mandatory Prepayment Event under Clause [           ] of [specify’ document] is
outstanding] and the following steps are being taken to remedy it [           ].
	 
	3.	 	With respect to the Calculation Period ending on [insert Repayment Date] the Debt Service Ratio
was [•] calculated on the basis of the figures in the table below.





	 	 	 	 	 
	Relevant figures for Calculation Period	 	US$	 
	Gross Revenues received
	 	 	 	 
	Operating Expenses payable
	 	 	 	 
	Financing Costs accrued
	 	 	 	 
	Financing Principal payable
	 	 	 	 
	CAPEX payable
	 	 	 	 





Yours faithfully,




	 	 	 	 	 
	 	
 	 
	 	[Senior Officer] 	 
	 	 	 



129









 






	 	 	 	 	 



SCHEDULE 7




INCIDENTAL VESSEL COSTS




	1.	 	Costs and expenses under the Management Agreement incurred in the Pre-Completion Period in
accordance with the Approved Budget attached as Appendix 12 up to US$34,100,000.
	 
	2.	 	Initial Debt Service Reserve Contribution up to US$25,000,000.




130









 











SCHEDULE 8




CALCULATION OF THE MANDATORY COST




	1.	 	General
	 
	(a)	 	The Mandatory Cost is to compensate a Lender for the cost of compliance with:






	 	(i)	 	the requirements of the Bank of England and/or the Financial Services Authority (or, in either
case, any other authority which replaces any of its functions); or
	 
	 	(ii)	 	the requirements of the European Central Bank.






	(b)	 	The Mandatory Cost is expressed as a percentage rate per annum.
	 
	(c)	 	The Mandatory Cost is the weighted average (weighted in proportion to the percentage share of
each Lender in the relevant Loan) of the rates for the Lenders calculated by the Facility Agent in
accordance with this Schedule on the first day of a Term (or as soon as possible after then).
	 
	(d)	 	The Facility Agent must distribute each amount of Mandatory Cost among the Lenders on the basis
of the rate for each Lender.
	 
	(e)	 	Any determination by the Facility Agent pursuant to this Schedule will be, in the absence of
manifest error, conclusive and binding on all the Parties.
	 
	2.	 	For a Lender lending from a Facility Office in the U.K.
	 
	(a)	 	The relevant rate for a Lender lending from a Facility Office in the U.K. is calculated in
accordance with the following formula:





	 	 	 

	E x 0.01
	   % per annum	 
	 


	 
	300
	 







	 	 	where on the day of application of the formula, E is calculated by the Facility Agent as being the
average of the rates of charge under the fees rules supplied by the Reference Banks to the Facility
Agent under paragraph (d) below and expressed in pounds per £1 million.
	 
	(b)	 	For the purposes of this paragraph 2:






	 	(i)	 	fees rules means the then current rules on periodic fees in the Supervision Manual of the FSA
Handbook or any other law or regulation as may then be in force for the payment of fees for the
acceptance of deposits;
	 
	 	(ii)	 	fee tariffs means the fee tariffs specified in the fees rules under fee-block Category Al
(Deposit acceptors) (ignoring any minimum fee or zero rated fee required pursuant to the fees rules
but applying any applicable discount rate); and
	 
	 	(iii)	 	tariff base has the meaning given to it in, and will be calculated in accordance with, the
fees rules.






	(c)	 	Each rate calculated in accordance with the formula is, if necessary, rounded upward to four
decimal places.




131









 












	(d)	 	If requested by the Facility Agent, each Reference Bank must, as soon as practicable after
publication by the Financial Services Authority, supply to the Facility Agent the rate of charge
payable by that Reference Bank to the Financial Services Authority under the fees rules for that
financial year of the Financial Services Authority (calculated by that Reference Bank as being the
average of the fee tariffs applicable to that Reference Bank for that financial year) and expressed
in pounds per £1 million of the tariff base of that Reference Bank.
	 
	(e)	 	Each Lender must supply to the Facility Agent the information required by it to make a
calculation of the rate for that Lender. In particular, each Lender must supply the following
information on or prior to the date on which it becomes a Lender:






	 	(i)	 	the jurisdiction of its Facility Office; and
	 
	 	(ii)	 	any other information that the Facility Agent reasonably requires for that purpose.






	 	 	Each Lender must promptly notify the Facility Agent of any change to the information supplied to it
under this paragraph.
	 
	(f)	 	The rates of charge of each Reference Bank for the purpose of E above are determined by the
Facility Agent based upon the information supplied to it under paragraphs (d) and (e) above. Unless
a Lender notifies the Facility Agent to the contrary, the Facility Agent may assume that the
Lender’s obligations in respect of cash ratio deposits and special deposits are the same as those
of a typical bank from its jurisdiction of incorporation with a Facility Office in the U.K.
	 
	(g)	 	The Facility Agent has no liability to any Party if its calculation over or under compensates
any Lender. The Facility Agent is entitled to assume that the information provided by any Lender or
Reference Bank under this Schedule is true and correct in all respects.
	 
	3.	 	For a Lender lending from a Facility Office in a Participating Member State
	 
	(a)	 	The relevant rate for a Lender lending from a Facility Office in a Participating Member State
is the percentage rate per annum notified by that Lender to the Facility Agent. This percentage
rate per annum must be certified by that Lender in its notice to the Facility Agent as its
reasonable determination of the cost (expressed as a percentage of that Lender’s share in all Loans
made from that Facility Office) of complying with the minimum reserve requirements of the European
Central Bank in respect of Loans made from that Facility Office.
	 
	(b)	 	If a Lender fails to specify a rate under paragraph (a) above, the Facility Agent will assume
that the Lender has not incurred any such cost.
	 
	4.	 	Changes
	 
	(a)	 	The Facility Agent may, after consultation with the Owner and the Lenders, determine and notify
all the Parties of any amendment to this Schedule which is required to reflect:






	 	(i)	 	any change in law or regulation; or
	 
	 	(ii)	 	any requirement imposed by the Bank of England, the Financial Services Authority or the
European Central Bank (or, in any case, any successor authority).






	(b)	 	If the Facility Agent, after consultation with the Owner, determines that the Mandatory Cost
for a Lender lending from a Facility Office in the U.K. can be calculated by reference to a screen,
the Facility Agent may notify all the Parties of any amendment to this Agreement which is required
to reflect this.




132









 











APPENDIX 1




FORM OF DELIVERY GENERAL ASSIGNMENT



133









 





APPENDIX 2




FORM OF MORTGAGE



134









 





APPENDIX 3




FORM OF CHARTER ASSIGNMENT



135









 





APPENDIX 4




APPROVED BUDGET



136









 





SIGNATORIES




DRILLSHIP KITHIRA OWNERS INC. — CREDIT FACILITY AGREEMENT



Owner




Signed by

as attorney for

DRILLSHIP KITHIRA OWNERS INC.

in the presence of:




Witness:



The Bookrunner and the Mandated Lead Arranger



By:



as authorised signatory for



DEUTSCHE BANK AG, LONDON BRANCH









137









 







The Lenders



By:



as authorised signatory for



DEUTSCHE BANK AG, LONDON BRANCH



By:



as attorney for



EKSPORTFINANS ASA



By:



as attorney for



THE EXPORT-IMPORT BANK OF KOREA



By:



as authorised signatory for



DVB BANK N.V., NORDIC BRANCH









138









 







By:



as authorised signatory for



HELABA LANDESBANK HESSEN-THÜRINGEN GIROZENTRALE, NEW YORK BRANCH



The Swap Banks



By:



as authorised signatory for



DEUTSCHE BANK AG, LONDON BRANCH



The Facility Agent



By:



as attorney for



DEUTSCHE BANK LUXEMBOURG S.A.



The Security Trustee



By:



as attorney for



DEUTSCHE BANK AG FILIALE DEUTSCHLANDGESCHAFT





139











 





SIGNATORIES




KITHIRA — AMENDMENT AND RESTATEMENT AGREEMENT TO CREDIT AGREEMENT



Owner




Signed by
ZIAD NAKHLEH



as attorney for /s/ Ziad Nakhleh

DRILLSHIP KITHIRA OWNERS INC.

in the presence of:



Witness: /s/ Stelios N. Deverakis




STELIOS N. DEVERAKIS

     Attorney-at-law

80 Kifisias Avenue — OR. 151 25 Marousl

          Athens — Greece

Tel.: +30 210614810. Fax: + 30 2106140267



The Bookrunner and the Mandated Lead Arranger



By:



as authorized signatory for



DEUTSCHE BANK AG, LONDON BRANCH




The Swap Bank




By:




as authorised signatory for



DEUTSCHE BANK AG, LONDON BRANCH




The Facility Agent for itself and on behalf of each Lender



By:

 


as attorney for



DEUTSCHE BANK LUXEMBOURG S.A.






 









 








SIGNATORIES




KITHIRA — AMENDMENT AND RESTATEMENT AGREEMENT TO CREDIT AGREEMENT




Owner




Signed by

as attorney for

DRILLSHIP KITHIRA OWNERS INC.

in the presence of:



Witness:



The Bookrunner and the Mandated Lead Arranger



By: /s/ Alexander Paixo



as authonsed signatory for




DEUTSCHE BANK AG, LONDON BRANCH



The Swap Bank



By: /s/ Alexander Paixo



as authorised signatory for




DEUTSCHE BANK AG, LONDON BRANCH




The Facility Agent for itself and on behalf of each Lender



By:



as attorney for




DEUTSCHE BANK LUXEMBOURG S.A.






 









 








SIGNATORIES




KITHIRA — AMENDMENT AND RESTATEMENT AGREEMENT TO CREDIT AGREEMENT




Owner




Signed by

as attorney for

DRILLSHIP KITHIRA OWNERS INC.

in the presence of:




Witness:




The Bookrunner and the Mandated Lead Arranger




By:




as authorised signatory for




DEUTSCHE BANK AG, LONDON BRANCH




The Swap Bank



By:



as authorised signatory for




DEUTSCHE BANK AG, LONDON BRANCH



The Facility Agent for itself and on behalf of each Lender



By: /s/
Philippi
                              
/s/ Ewerhardy 

       Philippi                                     Ewerhardy



as attorney for






DEUTSCHE BANK LUXEMBOURG S.A.





 









 








The Security Trustee



By: /s/
Duhmert                 /s/
Stein

       Duhmert                      Stein



as authorised signatories for






DEUTSCHE
BANK AG FILIALE DEUTSCHLANDGESCHÄFT