Prepared by R.R. Donnelley Financial -- EX-10.14




 Exhibit 10.14 

LEASE AGREEMENT 
 THIS
LEASE AGREEMENT (this “Lease”) is made this 14th day of February, 2013, between ARE-TECHNOLOGY CENTER SSF, LLC, a Delaware limited liability company
(“Landlord”), and CALITHERA BIOSCIENCES, INC., a Delaware corporation (“Tenant”). 
  

			
	Building:	  	343 Oyster Point Boulevard, South San Francisco, California
		
	Premises:	  	That portion of the Building, containing approximately 17,507 rentable square feet, determined by Landlord, as shown on Exhibit A.
		
	Project:	  	The real property on which the Building in which the Premises are located, together with all improvements thereon and appurtenances thereto as described on Exhibit B, currently consisting of the buildings described as 341
and 343 Oyster Point Boulevard, South San Francisco, California.
		
	Base Rent:	  	Months 1 — 12: *$2.60 per rentable square foot of the Premises per month
		  	Months 13 — 24: *$2.80 per rentable square foot of the Premises per month
		
		  	*Subject to Section 3(a)

 Rentable Area of Premises: 17,507 sq. ft. 

Rentable Area of Building: 53,980 sq. ft. 

Building’s Share of Project: 50% 
 Rentable Area
of Project: 107,960 sq. ft. 
 Tenant’s Share of Operating Expenses for the Building: 32.4396 (Subject to the second paragraph of
Section 5) 
 Tenant’s Share of Operating Expenses for the Project: 16.2296 (Subject to the second paragraph of
Section 5) 
  

			
	Security Deposit: $45,518.20	 	Target Commencement Date: July 1, 2013

  

			
	Base Term:	  	Beginning on the Commencement Date and ending 24 months from the first day of the first full month following the Commencement Date.
		
	Permitted Use:	  	Research and development laboratory, related office and other related uses consistent with the character of the Project and otherwise in compliance with the provisions of Section 7 hereof.

  

			
	Address for Rent Payment:	  	Landlord’s Notice Address:
	P.O. Box 975383	  	385 E. Colorado Boulevard, Suite 299
	Dallas, TX 75397-5383	  	Pasadena, CA 91101
		  	Attention: Corporate Secretary

 Tenant’s Notice Address: 

343 Oyster Point Boulevard 
 South San Francisco, California 94080

 Attention: Lease Administrator 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 2

  

The following Exhibits and Addenda are attached hereto and incorporated herein by this reference: 

 

			
	[X] EXHIBIT A - PREMISES DESCRIPTION	  	[X] EXHIBIT B - DESCRIPTION OF PROJECT
	[X] EXHIBIT C - WORK LETTER	  	[X] EXHIBIT D - COMMENCEMENT DATE
	[X] EXHIBIT E - RULES AND REGULATIONS	  	[X] EXHIBIT F - TENANT’S PERSONAL PROPERTY

 1. Lease of Premises. Upon and subject to all of the terms and conditions hereof (including, without
limitation, the fulfillment of Landlord’s obligation to Deliver the Landlord’s Work Substantially Completed in accordance with the Work Letter attached hereto as Exhibit C), Landlord hereby leases the Premises to Tenant and Tenant
hereby leases the Premises from Landlord. The portions of the Project which are for the non-exclusive use of tenants of the Project are collectively referred to herein as the “Common Areas.” Landlord reserves the right to modify Common
Areas, provided that such modifications do not materially adversely affect Tenant’s use of the Premises for the Permitted Use. 
 2.
Delivery; Acceptance of Premises; Commencement Date. Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed
(“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises. Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as
provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure Delays and Tenant Delays, provided that delays caused by Force Majeure shall not extend the Target
Completion Date for more than an additional 90 days, this Lease may be terminated by Landlord or Tenant by written notice to the other, and if so terminated by either: (a) the Security Deposit, or any balance thereof (i.e., after deducting
therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect
to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Force Majeure Delays,” “Tenant Delays” and “Substantially
Completed” shall have the meanings set forth for such terms in the Work Letter. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 90 day period (as such date may be extended for delays
caused by Tenant Delays and Force Majeure as provided for above), such right to void this Lease shall be waived and this Lease shall remain in full force and effect. 

The “Commencement Date” shall be the earlier of: (i) the date Landlord Delivers the entire Premises to Tenant; and
(ii) the date Landlord could have Delivered the entire Premises but for Tenant Delays. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, and the expiration date of the Term when such
are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect
Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease and any Extension Terms which Tenant may elect pursuant to Section 39 hereof. 

Subject to the provisions of Section 6 of the Work Letter, Landlord shall permit Tenant access to the Premises for a period of 10
days prior to the Commencement Date for Tenant’s installation of furniture, fixtures and equipment (“FF&E Installation”), provided that such FF&E Installation is coordinated with Landlord, and Tenant complies with the
Lease and all other reasonable restrictions and conditions Landlord may impose. All such access shall be during normal business hours. Any access to the Premises by Tenant before the Commencement Date shall be subject to all of the terms and
conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses. 
 During the Term, Tenant shall have the right
to use the furniture belonging to Landlord located in the Premises as of the Commencement Date (“Landlord’s Furniture”), as depicted on the Space Plan attached to the Work Letter as Schedule 1. Tenant shall have no right
to remove any of Landlord’s Furniture from the Premises without Landlord’s prior written consent and any remaining Landlord’s Furniture shall be returned to Landlord at the expiration or earlier termination of the Term in
substantially the same condition as received by Tenant, except for ordinary wear and tear and damage by fire or casualty. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 3

  

For the period of 90 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an
Operating Expense), be responsible for any repairs that are required to be made to the Building Systems (as defined in Section 13) serving the Premises and to the equipment that Landlord installed in the Premises as part of the Tenant
Improvements, unless Tenant or any Tenant Party was responsible for the cause of such repair, in which case Tenant shall pay the cost. 

Except as set forth in the Work Letter and this Lease: (i) Tenant shall accept the Premises and Landlord’s Furniture in their
condition as of the Commencement Date, subject to all applicable Legal Requirements (as defined in Section 7 hereof); (ii) Landlord shall have no obligation for any defects in the Premises or Landlord’s Furniture; and
(iii) Tenant’s taking possession of the Premises and Landlord’s Furniture shall be conclusive evidence that Tenant accepts the Premises and Landlord’s Furniture and that the Premises and Landlord’s Furniture were in good
condition at the time possession was taken. 
 Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any
representation or warranty with respect to the condition of all or any portion of the Premises, Landlord’s Furniture or the Project, and/or the suitability of the Premises, Landlord’s Furniture or the Project for the conduct of
Tenant’s business, and Tenant waives any implied warranty that the Premises, Landlord’s Furniture or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the
subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s
representations, warranties, acknowledgments and agreements contained herein. 
 3. Rent. 

(a) Base Rent. The first month’s Base Rent and the Security Deposit shall be due and payable on delivery of an executed copy of
this Lease to Landlord. Tenant shall pay to Landlord in advance, without demand, abatement, deduction or set-off, monthly installments of Base Rent on or before the first day of each calendar month during the Term hereof, in lawful money of the
United States of America, at the office of Landlord for payment of Rent set forth above, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments of Base Rent for any fractional calendar month
shall be prorated. The obligation of Tenant to pay Base Rent and other sums to Landlord and the obligations of Landlord under this Lease are independent obligations. Tenant shall have no right at any time to abate, reduce, or set-off any Rent (as
defined in Section 5) due hereunder except for any abatement as may be expressly provided in this Lease. 
 Notwithstanding
anything to the contrary contained in this Lease, commencing on the Commencement Date through the expiration of the Base Term of the Lease. Tenant shall be required to pay Base Rent with respect to only 17,000 rentable square feet of the Premises.
Upon the commencement of any Extension Term, Tenant shall pay Base Rent with respect to the entire Premises. 
 (b) Additional Rent.
In addition to Base Rent, Tenant agrees to pay to Landlord as additional rent (“Additional Rent”): (i) Tenant’s Share of “Operating Expenses” (as defined in Section 5), and (ii) any and all other
amounts Tenant assumes or agrees to pay under the provisions of this Lease, including, without limitation, any and all other sums that may become due by reason of any default of Tenant or failure to comply with the agreements, terms, covenants and
conditions of this Lease to be performed by Tenant, after any applicable notice and cure period. 
 4. Base Rent Adjustments. Base
Rent shall be increased during the Base Term as provided for in the schedule set forth on page 1 of this Lease subject to Section 3(a) above. Base Rent, as so adjusted, shall thereafter be due as provided herein. Base Rent adjustments
for any fractional calendar month shall be prorated. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 4

  

5. Operating Expense Payments. Landlord shall deliver to Tenant a written estimate of Operating Expenses for each calendar year during
the Term (the “Annual Estimate”), which may be revised by Landlord from time to time during such calendar year but not more frequently than quarterly. Commencing on the Commencement Date and continuing thereafter on the first day of
each month during the Term. Tenant shall pay Landlord an amount equal to 1/12th of Tenant’s Share of the Annual Estimate. Payments for any fractional calendar month shall be prorated. 

Notwithstanding anything to the contrary contained herein, commencing on the Commencement Date through the expiration of the Base Term of the
Lease. Tenant shall be required to pay Operating Expenses (other than Utilities) with respect to only 17,000 rentable square feet of the Premises (which shall equal 31.4996 with respect to Building and 157596 with respect to the Project). Upon the
commencement of any Extension Term, Tenant shall pay Operating Expenses with respect to the entire Premises. Notwithstanding the foregoing, commencing on the Commencement Date and continuing throughout the Term, Tenant shall pay Tenant’s Share
of Utilities with respect to the entire Premises. 
 The term “Operating Expenses” means all costs and expenses of any kind
or description whatsoever incurred or accrued each calendar year by Landlord with respect to the Building (including the Building’s Share of all costs and expenses of any kind or description incurred or accrued by Landlord with respect to the
Project which are not specific to the Building or any other building located in the Project) (including, without duplication, Taxes (as defined in Section 9), capital repairs and improvements amortized over the lesser of 10 years and the
useful life of such capital items, and the costs of Landlord’s third party property manager (not to exceed 3% of Base Rent) or, if there is no third party property manager, administration rent in the amount of 3.0% of Base Rent), excluding
only: 
 (a) the original design and/or construction costs of the Project and renovation prior to the date of the Lease and costs of
correcting defects in such original design and/or construction or renovation; 
 (b) capital expenditures for expansion of the Project; 

(c) interest, principal payments of Mortgage (as defined in Section 27) debts of Landlord, financing costs and amortization of
funds borrowed by Landlord, whether secured or unsecured and all payments of base rent (but not taxes or operating expenses) under any ground lease or other underlying lease of all or any portion of the Project; 

(d) depreciation of the Project (except for capital improvements amortized as required herein, the cost of which are includable in Operating
Expenses); 
 (e) advertising, legal and space planning expenses and leasing commissions and other costs and expenses incurred in procuring
and leasing space to tenants for the Project, including any leasing office maintained in the Project, free rent and construction allowances for tenants; 

(f) legal and other expenses incurred in the negotiation or enforcement of leases; 

(g) completing, fixturing, improving, renovating, painting, redecorating or other work, which Landlord pays for or performs for other tenants
within their premises, and costs of correcting defects in such work; 
 (h) costs to be reimbursed by other tenants of the Project or Taxes
to be paid directly by Tenant or other tenants of the Project, whether or not actually paid; 
 (i) salaries, wages, benefits and other
compensation paid to officers and employees of Landlord who are not assigned in whole or in part to the operation, management, maintenance or repair of the Project; 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 5

  

(j) general organizational, administrative and overhead costs relating to maintaining Landlord’s existence, either as a corporation,
partnership, or other entity, including general corporate, legal and accounting expenses; 
 (k) costs (including attorneys’ fees and
costs of settlement, judgments and payments in lieu thereof) incurred in connection with disputes with tenants, other occupants, or prospective tenants, and costs and expenses, including legal fees, incurred in connection with negotiations or
disputes with employees, consultants, management agents, leasing agents, purchasers or mortgagees of the Building; 
 (l) costs (including
attorneys’ fees and costs of settlement, judgments and payments in lieu thereof) incurred by Landlord due to the violation by Landlord, its employees, agents or contractors or any tenant of the terms and conditions of any lease of space in the
Project or any Legal Requirement (as defined in Section 7); 
 (m) penalties, fines or interest incurred as a result of Landlord’s
inability or failure to make payment of Taxes and/or to file any tax or informational returns when due, or from Landlord’s failure to make any payment of Taxes required to be made by Landlord hereunder before delinquency; 

(n) costs of goods and/or services in, for, or to the Project paid to Landlord or to subsidiaries or affiliates of Landlord for goods and/or
services in, for, or to the Project to the extent the same exceeds the costs of such goods and/or services rendered by unaffiliated third parties on a competitive basis; 

(o) costs of Landlord’s charitable or political contributions, or of fine art (and insurance therefor) maintained at the Project; 

(p) costs in connection with services (including electricity), items or other benefits of a type which are not standard for the Project and
which are not available to Tenant without specific charges therefor, but which are provided to another tenant or occupant of the Project, whether or not such other tenant or occupant is specifically charged therefor by Landlord; 

(q) costs incurred in the sale or refinancing of the Project; 

(r) net income taxes of Landlord or the owner of any interest in the Project, franchise, capital stock, gift, estate or inheritance taxes or
any federal, state or local documentary taxes imposed against the Project or any portion thereof or interest therein; 
 (s) any costs
incurred to remove, study, test, remediate or otherwise related to the presence of Hazardous Materials in or about the Building or the Project, which Hazardous Materials Tenant proves (i) existed prior to the Commencement Date,
(ii) originated from any separately demised tenant space within the Project other than the Premises or (iii) were not brought upon, kept, used, stored, handled, treated, generated in, or released or disposed of from, the Project by Tenant
or any Tenant Party (as herein defined); 
 (t) costs of repairs and other work occasioned by fire, windstorm, or other casualty for which
Landlord is reimbursed by insurance or for which Landlord would have been reimbursed by insurance if Landlord failed to maintain the insurance which Landlord is required to maintain under this Lease; 

(u) wages, salaries, or other compensation paid to any executive employees above the grade of building manager; and 

(v) any expenses otherwise includable within Operating Expenses to the extent actually reimbursed by persons other than tenants of the Project
under leases for space in the Project. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 6

  

Within 90 days after the end of each calendar year (or such longer period as may be reasonably required). Landlord shall furnish to Tenant a
statement (an “Annual Statement”) showing in reasonable detail: (a) the total and Tenant’s Share of actual Operating Expenses for the previous calendar year, and (b) the total of Tenant’s payments in respect of
Operating Expenses for such year. If Tenant’s Share of actual Operating Expenses for such year exceeds Tenant’s payments of Operating Expenses for such year, the excess shall be due and payable by Tenant as Rent within 30 days after
delivery of such Annual Statement to Tenant. If Tenant’s payments of Operating Expenses for such year exceed Tenant’s Share of actual Operating Expenses for such year Landlord shall pay the excess to Tenant within 30 days after delivery of
such Annual Statement, except that after the expiration, or earlier termination of the Term or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. 

The Annual Statement shall be final and binding upon Tenant unless Tenant, within 90 days after Tenant’s receipt thereof, shall contest
any item therein by giving written notice to Landlord, specifying each item contested and the reason therefor. lf, during such 90 day period, Tenant reasonably and in good faith questions or contests the accuracy of Landlord’s statement of
Tenant’s Share of Operating Expenses, Landlord will provide Tenant with access to Landlord’s books and records relating to the operation of the Project and such information as Landlord reasonably determines to be responsive to
Tenant’s questions (the “Expense Information”). If after Tenant’s review of such Expense Information, Landlord and Tenant cannot agree upon the amount of Tenant’s Share of Operating Expenses, then Tenant shall have
the right to have an independent regionally recognized public accounting firm selected by Tenant, working pursuant to a fee arrangement other than a contingent fee (at Tenant’s sole cost and expense) and approved by Landlord (which approval
shall not be unreasonably withheld or delayed), audit and/or review the Expense Information for the year in question (the “Independent Review”). The results of any such Independent Review shall be binding on Landlord and Tenant. If
the Independent Review shows that the payments actually made by Tenant with respect to Operating Expenses for the calendar year in question exceeded Tenant’s Share of Operating Expenses for such calendar year. Landlord shall at Landlord’s
option either (i) credit the excess amount to the next succeeding installments of estimated Operating Expenses or (ii) pay the excess to Tenant within 30 days after delivery of such statement, except that after the expiration or earlier
termination of this Lease or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. If the Independent Review shows that Tenant’s payments with respect to
Operating Expenses for- such calendar year were less than Tenant’s Share of Operating Expenses for the calendar year. Tenant shall pay the deficiency to Landlord within 30 days after delivery of such statement. If the Independent Review shows
that Tenant has overpaid with respect to Operating Expenses by more than 5% then Landlord shall reimburse Tenant for all costs incurred by Tenant for the Independent Review. Operating Expenses for the calendar years in which Tenant’s obligation
to share therein begins and ends shall be prorated. Notwithstanding anything set forth herein to the contrary, if the Building is not at least 9596 occupied on average during any year of the Term, Tenant’s Share of Operating Expenses for the
Building for such year shall be computed as though the Building had been 9596 occupied on average during such year. 

“Tenant’s Share” shall, subject to the provisions of the second paragraph of this Section 5, be the
percentages set forth on the first page of this Lease as Tenant’s Share of Operating Expenses for the Building and Tenant’s Share of Operating Expenses for the Project, as reasonably adjusted by Landlord for changes in the physical size of
the Premises or the Project occurring thereafter. Landlord may equitably increase Tenant’s Share for any item of expense or cost reimbursable by Tenant that relates to a repair, replacement, or service that benefits only the Premises or only a
portion of the Project that includes the Premises or that varies with Tenant’s occupancy or use. Base Rent, Tenant’s Share of Operating Expenses and all other amounts payable by Tenant to Landlord hereunder are collectively referred to
herein as “Rent.” 
 6. Security Deposit. Tenant shall deposit with Landlord, upon delivery of an executed copy of
this Lease to Landlord, a security deposit (the “Security Deposit”) for the performance of all of Tenant’s obligations hereunder in the amount set forth on page 1 of this Lease, which Security Deposit shall be in the form of an
unconditional and irrevocable letter of credit (the “Letter of Credit”): (i) in form and substance reasonably satisfactory to Landlord, (ii) naming Landlord as beneficiary, (iii) expressly allowing Landlord to draw
upon it at any time from time to time by delivering to the issuer notice that 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 7

  


Landlord is entitled to draw thereunder, (iv) issued by Silicon Valley Bank or another FDIC-insured financial institution satisfactory to Landlord, and (v) redeemable by presentation of
a sight draft in the state of Landlord’s choice. If Tenant does not provide Landlord with a substitute Letter of Credit complying with all of the requirements hereof at least 10 days before the stated expiration date of any then current Letter
of Credit, Landlord shall have the right to draw the full amount of the current Letter of Credit and hold the funds drawn in cash without obligation for interest thereon as the Security Deposit. The Security Deposit shall be held by Landlord as
security for the performance of Tenant’s obligations under this Lease. The Security Deposit is not an advance rental deposit or a measure of Landlord’s damages in case of Tenant’s default. Upon each occurrence of a Default (as defined
in Section 20), Landlord may use all or any part of the Security Deposit to pay delinquent payments due under this Lease, future rent damages under California Civil Code Section 1951.2, and the cost of any damage, injury, expense or
liability caused by such Default, without prejudice to any other remedy provided herein or provided by law. Landlord’s right to use the Security Deposit under this Section 6 includes the right to use the Security Deposit to pay future rent
damages following the termination of this Lease pursuant to Section 21(c) below. Upon any use of all or any portion of the Security Deposit, Tenant shall pay Landlord on demand the amount that will restore the Security Deposit to the amount set
forth on Page 1 of this Lease. Tenant hereby waives the provisions of any law, now or hereafter in force, including, without limitation, California Civil Code Section 1950.7, which provide that Landlord may claim from a security deposit only
those sums reasonably necessary to remedy defaults in the payment of Rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums reasonably necessary to compensate Landlord for
any other loss or damage, foreseeable or unforeseeable, caused by the act or omission of Tenant or any officer, employee, agent or invitee of Tenant. Upon bankruptcy or other debtor-creditor proceedings against Tenant, the Security Deposit shall be
deemed to be applied first to the payment of Rent and other charges due Landlord for periods prior to the filing of such proceedings. Upon any such use of all or any portion of the Security Deposit, Tenant shall, within 5 days after demand from
Landlord, restore the Security Deposit to its original amount. If Tenant shall fully perform every provision of this Lease to be performed by Tenant, the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which
Landlord is entitled under the provisions of this Lease), shall be returned to Tenant (or, at Landlord’s option, to the last assignee of Tenant’s interest hereunder) within 90 days after the expiration or earlier termination of this Lease.

 If Landlord transfers its interest in the Project or this Lease, Landlord shall either (a) transfer any Security Deposit then held
by Landlord to a person or entity assuming Landlord’s obligations under this Section 6, or (b) return to Tenant any Security Deposit then held by Landlord and remaining after the deductions permitted herein. Upon such transfer to and
assumption by such transferee or the return of the Security Deposit to Tenant, Landlord shall have no further obligation with respect to the Security Deposit, and Tenant’s right to the return of the Security Deposit shall apply solely against
Landlord’s transferee. The Security Deposit is not an advance rental deposit or a measure of Landlord’s damages in case of Tenant’s default. Landlord’s obligation respecting the Security Deposit is that of a debtor, not a
trustee, and no interest shall accrue thereon. 
 Notwithstanding anything to the contrary contained herein, concurrent with the delivery by
Tenant of an executed copy of this Lease to Landlord, Tenant shall deliver to Landlord an amendment, in a form acceptable to Landlord in its sole and absolute discretion (“LC Amendment”), to that certain Letter of Credit in the
amount of $37,047.00 issued by Silicon Valley Bank and dated June 31, 2012 (“Existing Letter of Credit”), currently being held by Landlord pursuant to that certain Lease Agreement between Landlord and Tenant dated July 7,
2010, as the same has been or may in the future be amended (“Existing Lease”). The LC Amendment shall increase the amount of the Existing Letter of Credit to the full amount of the Security Deposit required under this Lease. Tenant
acknowledges and agrees that Landlord shall have all of the rights provided for in this Section 6 to the Existing Letter of Credit, as amended by the LC Amendment, with respect to and in connection with this Lease (in addition to the
Existing Lease), including, without limitation, the right to draw down on the Existing Letter of Credit, as amended by the LC Amendment. Tenant agrees that if Landlord makes a draw on the Existing Letter of Credit under the Existing Lease, Tenant
shall restore the Existing Letter of Credit, as amended by the LC Amendment, to its full amount within 5 days after demand from Landlord. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 8

  

7. Use. The Premises shall be used solely for the Permitted Use set forth in the basic lease provisions on page 1 of this Lease, and in
compliance with all laws, orders, judgments, ordinances, regulations, codes, directives, permits, licenses, covenants and restrictions now or hereafter applicable to the Premises, and to the use and occupancy thereof, including, without limitation,
the Americans With Disabilities Act, 42 U.S.C. § 12101, et seq. (together with the regulations promulgated pursuant thereto, “ADA”) (collectively, “Legal Requirements” and each, a “Legal
Requirement”). Tenant shall, upon 5 days’ written notice from Landlord, discontinue any use of the Premises which is declared by any Governmental Authority (as defined in Section 9) having jurisdiction to be a violation of
a Legal Requirement. Tenant will not use or permit the Premises to be used for any purpose or in any manner that would void Tenant’s or Landlord’s insurance, increase the insurance risk, or cause the disallowance of any sprinkler or other
credits. Tenant shall not permit any part of the Premises to be used as a “place of public accommodation”, as defined in the ADA or any similar legal requirement. Tenant shall reimburse Landlord promptly upon demand for any additional
premium charged for any such insurance policy by reason of Tenant’s failure to comply with the provisions of this Section or otherwise caused by Tenant’s use and/or occupancy of the Premises. Tenant will use the Premises in a careful, safe
and proper manner and will not commit or permit waste, overload the floor or structure of the Premises, subject the Premises to use that would damage the Premises or obstruct or interfere with the rights of Landlord or other tenants or occupants of
the Project, including conducting or giving notice of any auction, liquidation, or going out of business sale on the Premises, or using or allowing the Premises to be used for any unlawful purpose. Tenant shall cause any equipment or machinery to be
installed in the Premises so as to reasonably prevent sounds or vibrations from the Premises from extending into Common Areas, or other space in the Project. Tenant shall not place any machinery or equipment weighing 500 pounds or more in or upon
the Premises or transport or move such items through the Common Areas of the Project or in the Project elevators without the prior written consent of Landlord. Except as may be provided under the Work Letter, Tenant shall not, without the prior
written consent of Landlord, use the Premises in any manner which will require ventilation, air exchange, heating, gas, steam, electricity or water beyond the existing capacity of the Project as proportionately allocated to the Premises based upon
Tenant’s Share as usually furnished for the Permitted Use. 
 Landlord shall be responsible for the compliance of the Common Areas of
the Project with the Legal Requirements as of the Commencement Date. Following the Commencement Date, Landlord shall, as an Operating Expense (to the extent such Legal Requirement is generally applicable to similar buildings in the area in which the
Project is located) and at Tenant’s expense (to the extent such Legal Requirement is triggered by reason of Tenant’s, as compared to other tenants of the Project, specific use of the Premises or Tenant’s alterations) make any
alterations or modifications to the Common Areas or the exterior of the Building that are required by Legal Requirements. Except as set forth in the two sentences immediately preceding, Tenant, at its sole expense, shall make any alterations or
modifications to the interior of the Premises that are required by Legal Requirements (including, without limitation, compliance of the Premises with the ADA) related to Tenant’s use or occupancy of the Premises. Except as otherwise expressly
set forth in this Lease. Tenant shall be responsible for any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action, damages or judgments, and all reasonable expenses incurred in investigating or resisting the same
(including, without limitation, reasonable attorneys’ fees, charges and disbursements and costs of suit) (collectively, “Claims”) arising out of or in connection with Legal Requirements, and Tenant shall indemnify, defend, hold and
save Landlord harmless from and against any and all Claims arising out of or in connection with any failure of the Premises to comply with any Legal Requirement. 

8. Holding Over. lf, with Landlord’s express written consent, Tenant retains possession of the Premises after the termination of
the Term, (i) unless otherwise agreed in such written consent, such possession shall be subject to immediate termination by Landlord at any time, (ii) all of the other terms and provisions of this Lease (including, without limitation, the
adjustment of Base Rent pursuant to Section 4 hereof) shall remain in full force and effect (excluding any expansion or renewal option or other similar right or option) during such holdover period, (iii) Tenant shall continue to pay
Base Rent in the amount payable upon the date of the expiration or earlier termination of this Lease or such other amount as Landlord may indicate, in Landlord’s sole and absolute discretion, in such written consent, and (iv) all other
payments shall continue under the terms of this Lease. If Tenant remains in possession of the 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 9

  


Premises after the expiration or earlier termination of the Term without the express written consent of Landlord, (A) Tenant shall become a tenant at sufferance upon the terms of this Lease
except that the monthly rental shall be equal to 150% of Rent in effect during the last 30 days of the Term, and (B) Tenant shall be responsible for all damages suffered by Landlord resulting from or occasioned by Tenant’s holding over,
including consequential damages. No holding over by Tenant, whether with or without consent of Landlord, shall operate to extend this Lease except as otherwise expressly provided, and this Section 8 shall not be construed as consent for
Tenant to retain possession of the Premises. Acceptance by Landlord of Rent after the expiration of the Term or earlier termination of this Lease shall not result in a renewal or reinstatement of this Lease. 

9. Taxes. Landlord shall pay, as part of Operating Expenses, all taxes, levies, fees, assessments and governmental charges of any kind,
existing as of the Commencement Date or thereafter enacted (collectively referred to as “Taxes”), imposed by any federal, state, regional, municipal, local or other governmental authority or agency, including, without limitation,
quasi-public agencies (collectively, “Governmental Authority”) during the Term, including, without limitation, all Taxes: (i) imposed on or measured by or based, in whole or in part, on rent payable to (or gross receipts
received by) Landlord under this Lease and/or from the rental by Landlord of the Project or any portion thereof, or (ii) based on the square footage, assessed value or other measure or evaluation of any kind of the Premises or the Project, or
(iii) assessed or imposed by or on the operation or maintenance of any portion of the Premises or the Project, including parking, or (iv) assessed or imposed by, or at the direction of, or resulting from Legal Requirements, or
interpretations thereof, promulgated by any Governmental Authority, or (v) imposed as a license or other fee, charge, tax, or assessment on Landlord’s business or occupation of leasing space in the Project. Landlord may contest by
appropriate legal proceedings the amount, validity, or application of any Taxes or liens securing Taxes. Taxes shall not include any net income taxes imposed on Landlord except to the extent such net income taxes are in substitution for any Taxes
payable hereunder. If any such Tax is levied or assessed directly against Tenant, then Tenant shall be responsible for and shall pay the same at such times and in such manner as the taxing authority shall require. Tenant shall pay, prior to
delinquency, any and all Taxes levied or assessed against any personal property or trade fixtures placed by Tenant in the Premises, whether levied or assessed against Landlord or Tenant. If any Taxes on Tenant’s personal property or trade
fixtures are levied against Landlord or Landlord’s property, or if the assessed valuation of the Project is increased by a value attributable to improvements in or alterations to the Premises, whether owned by Landlord or Tenant and whether or
not affixed to the real property so as to become a part thereof, higher than the base valuation on which Landlord from time-to-time allocates Taxes to all tenants in the Project, Landlord shall have the right, but not the obligation, to pay such
Taxes. Landlord’s determination of any excess assessed valuation shall be binding and conclusive, absent manifest error. The amount of any such payment by Landlord shall constitute Additional Rent due from Tenant to Landlord immediately upon
demand. 
 10. Parking. Subject to all matters of record, Force Majeure, a Taking (as defined in Section 19 below) and
the exercise by Landlord of its rights hereunder, Tenant shall have the right, at no additional cost to Tenant, in common with other tenants of the Project pro rata in accordance with the rentable area of the Premises and the rentable areas of the
Project occupied by such other tenants, to park in those areas designated for non-reserved parking, subject in each case to Landlord’s reasonable rules and regulations. As of the date of this Lease, Tenant’s pro rata share of parking is
equal to 2.8 parking spaces per 1,000 rentable square feet of the Premises. Landlord may allocate parking spaces among Tenant and other tenants in the Project pro rata as described above if Landlord determines that such parking facilities are
becoming crowded. Landlord shall not be responsible for enforcing Tenant’s parking rights against any third parties, including other tenants of the Project. 

Tenant acknowledges that Tenant may be required to comply with a Preliminary Transportation Demand Management Plan (“TDM”)
setting forth certain requirements relating to parking and transportation demand management which are binding on tenants in the Project and agrees to comply with the requirements of any such TDM. Tenant acknowledges that Operating Expenses shall
include expenses and assessments related to any such TDM. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 10

  

11. Utilities, Services. Landlord shall provide, subject to the terms of this Section 11, water, electricity, heat, light,
power, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), refuse and trash collection and janitorial services (collectively, “Utilities”). Landlord shall pay, as
Operating Expenses or subject to Tenant’s reimbursement obligation, for all Utilities used on the Premises, all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental
Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. Landlord may cause, at Tenant’s expense, any Utilities to be separately metered or charged directly to Tenant by the provider. Tenant shall pay
directly to the Utility provider, prior to delinquency, any separately metered Utilities and services which may be furnished to Tenant or the Premises during the Term. Tenant shall pay, as part of Operating Expenses, its share of all charges for
jointly metered Utilities based upon consumption, as reasonably determined by Landlord. No interruption or failure of Utilities, from any cause whatsoever other than Landlord’s willful misconduct, shall result in eviction or constructive
eviction of Tenant, termination of this Lease or the abatement of Rent. Tenant agrees to limit use of water and sewer with respect to Common Areas to normal restroom use. Tenant shall have access to the Premises and Utilities shall be available to
the Premises 24 hours per day, 7 days per week, except in the case of emergencies, as the result of Legal Requirements, the failure of any Utility provider to provide such Utilities, the performance by Landlord or any Utility provider of any
installation, maintenance or repairs, or any other temporary interruptions. 
 Landlord’s sole obligation for either providing
emergency generators or providing emergency back-up power to Tenant shall be: (i) to provide emergency generators with not less than the capacity of the emergency generators located in the Building as of the Commencement Date, and (ii) to
contract with a third party to maintain the emergency generators as per the manufacturer’s standard maintenance guidelines. Landlord shall have no obligation to provide Tenant with operational emergency generators or back-up power or to
supervise, oversee or confirm that the third party maintaining the emergency generators is maintaining the generators as per the manufacturer’s standard guidelines or otherwise. During any period of replacement, repair or maintenance of the
emergency generators when the emergency generators are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up
generator, or generators or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generators will be operational at all times or that emergency power will be available to
the Premises when needed. 
 12. Alterations and Tenant’s Property. Any alterations, additions, or improvements made to the
Premises by or on behalf of Tenant, including additional locks or bolts of any kind or nature upon any doors or windows in the Premises, but excluding installation, removal or realignment of furniture systems (other than removal of furniture systems
owned or paid for by Landlord) not involving any modifications to the structure or connections (other then by ordinary plugs or jacks) to Building Systems (as defined in Section 13) (“Alterations”) shall be subject to
Landlord’s prior written consent, which may be given or withheld in Landlord’s sole discretion if any such Alteration affects the structure or Building Systems and shall not be otherwise unreasonably withheld. If Landlord approves any
Alterations, Landlord may impose such conditions on Tenant in connection with the commencement, performance and completion of such Alterations as Landlord may deem appropriate in Landlord’s reasonable discretion. Any request for approval shall
be in writing, delivered not less than 15 business days in advance of any proposed construction, and accompanied by plans, specifications, bid proposals, work contracts and such other information concerning the nature and cost of the alterations as
may be reasonably requested by Landlord, including the identities and mailing addresses of all general contractors performing work or supplying materials. Landlord’s right to review plans and specifications and to monitor construction shall be
solely for its own benefit, and Landlord shall have no duty to ensure that such plans and specifications or construction comply with applicable Legal Requirements. Tenant shall cause, at its sole cost and expense, all Alterations to comply with
insurance requirements and with Legal Requirements and shall implement at its sole cost and expense any alteration or modification required by Legal Requirements as a result of any Alterations. Tenant shall pay to Landlord, as Additional Rent, on
demand an amount equal to 3`)/0 of all charges incurred by Tenant or its contractors or agents in connection with any Alteration to cover Landlord’s overhead and expenses for plan review, coordination, scheduling and supervision; provided,
however, that no fee shall be charged by Landlord if 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 11

  


Landlord’s involvement is limited to the review and approval of Tenant’s plans. Before Tenant begins any Alteration, Landlord may post on and about the Premises notices of
non-responsibility pursuant to applicable law. Tenant shall reimburse Landlord for, and indemnify and hold Landlord harmless from, any expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, delays caused by such
work, or inadequate cleanup. 
 Tenant shall furnish security or make other arrangements satisfactory to Landlord Cu assure payment for the
completion of all Alterations work free and clear of liens, and shall provide (and cause each contractor or subcontractor to provide) certificates of insurance for workers’ compensation and other coverage in amounts and from an insurance
company satisfactory to Landlord protecting Landlord against liability for personal injury or property damage during construction. Upon completion of any Alterations. Tenant shall deliver to Landlord: (i) sworn statements setting forth the
names of all contractors and subcontractors who did the work and final lien waivers from all such contractors and subcontractors; and (ii) “as built” plans for any such Alteration; if the nature of such Alteration requires such plans.

 Except for Removable Installations (as hereinafter defined), all Installations (as hereinafter defined) shall be and shall remain the
property of Landlord during the Term and following the expiration or earlier termination of the Term, shall not be removed by Tenant at any time during the Term, and shall remain upon and be surrendered with the Premises as a part thereof.
Notwithstanding the foregoing, Landlord may, at the time its approval of any such Installation is requested, notify Tenant that Landlord requires that Tenant remove such Installation upon the expiration or earlier termination of the Term, in which
event Tenant shall remove such Installation in accordance with the immediately succeeding sentence. Upon the expiration or earlier termination of the Term, Tenant shall remove (i) all wires, cables or similar equipment which Tenant has
installed in the Premises or in the risers or plenums of the Building, (ii) any Installations for which Landlord has given Tenant notice of removal in accordance with the immediately preceding sentence, and (iii) all of Tenant’s
Property (as hereinafter defined), and Tenant shall restore and repair any damage caused by or occasioned as a result of such removal, including, without limitation, capping off all such connections behind the walls of the Premises and repairing any
holes. During any restoration period beyond the expiration or earlier termination of the Term. Tenant shall pay Rent to Landlord as provided herein as if said space were otherwise occupied by Tenant. If Landlord is requested by Tenant or any lender,
lessor or other person or entity claiming an interest in any of Tenant’ Property to waive any lien Landlord may have against any of Tenant’s Property, and Landlord consents to such waiver, then Landlord shall be entitled to be paid as
administrative rent a fee of $1,000 per occurrence for its time and effort in preparing and negotiating such a waiver of lien. 
 For
purposes of this Lease, (x) “Removable Installations” means any items listed on Exhibit F attached hereto and any items agreed by Landlord in writing to be included on Exhibit F in the future,
(y) “Tenant’s Property” means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and
(z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment,
property and improvements built into the Premises no as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms,
walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch. 

13. Landlord’s Repairs. Landlord, as an Operating Expense (except to the extent expressly excluded from Operating Expenses in
Section 5), shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the
Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively,
“Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop
Building 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 12

  


Systems services when necessary(i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the reasonable judgment of Landlord, desirable
or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption;
provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs,
alterations or improvements. Tenant shall promptly give Landlord written notice of any repair of which Tenant becomes aware required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect
such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance.
Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as net forth herein.
Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18. 

14. Tenant’s Repairs. Except for those portions of the Premises for which Landlord is expressly responsible pursuant to
Section 13 hereof, during the Term, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and
the interior side of demising walls. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises. Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of
Landlord’s notice, and thereafter diligently prosecute such cure to completion. Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or
could create an emergency. Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost
of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises. 

15. Mechanic’s Liens. Tenant shall discharge, by bond or otherwise, any mechanic’s lien filed against the Premises or against
the Project for work claimed to have been done for, or materials claimed to have been furnished to, Tenant within 10 days after the filing thereof, at Tenant’s sole cost and shall otherwise keep the Premises and the Project free from any liens
arising out of work performed, materials furnished or obligations incurred by Tenant. Should Tenant fail to discharge any lien described herein. Landlord shall have the right, but not the obligation, to pay such claim or post a bond or otherwise
provide security to eliminate the lien as a claim against title to the Project and the cost thereof shall be immediately due from Tenant as Additional Rent. If Tenant shall lease or finance the acquisition of office equipment, furnishings, or other-
personal property of a removable nature utilized by Tenant in the operation of Tenant’s business, Tenant warrants that any Uniform Commercial Code Financing Statement filed as a matter of public record by any lessor or creditor of Tenant will
upon its face or by exhibit thereto indicate that such Financing Statement is applicable only to removable personal property of Tenant located within the Premises. In no event shall the address of the Project be furnished on the statement without
qualifying language as to applicability of the lien only to removable personal property, located in an identified suite held by Tenant. 

16. Indemnification. Tenant hereby indemnifies and agrees to defend, save and hold Landlord harmless from and against any and all
Claims for injury or death to persons or damage to property occurring within or about the Premises, arising directly or indirectly out of use or occupancy of the Premises or a breach or default by Tenant in the performance of any of its obligations
hereunder, unless caused solely by the willful misconduct or gross negligence of Landlord. Landlord shall not be liable to Tenant for, and Tenant assumes all risk of damage to, personal property (including, without limitation, loss of records kept
within the Premises). Tenant further waives any and all Claims for injury to Tenant’s business or loss of income relating to any such damage or destruction of personal property (including, without limitation, any loss of records). Landlord
shall not be liable for any damages arising from any act, omission or neglect of any tenant in the Project or of any other third party. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 13

  

17. Insurance. Landlord shall maintain all risk property and, if applicable, sprinkler damage insurance covering the full replacement
cost of the Project or such lesser coverage amount as Landlord may elect provided such coverage amount is not less than 9096 of such full replacement cost. Landlord shall further procure and maintain commercial general liability insurance
with a single loss limit of not less than $2,000,000 for bodily injury and property damage with respect to the Project. Landlord may, but is not obligated to, maintain such other insurance and additional coverages as it may deem necessary,
including, but not limited to, flood, environmental hazard and earthquake, loss or failure of building equipment, errors and omissions, rental loss during the period of repair or rebuilding, workers’ compensation insurance and fidelity bonds
for employees employed to perform services and insurance for any improvements installed by Tenant or which are in addition to the standard improvements customarily furnished by Landlord without regard to whether or not such are made a part of the
Project. All such insurance shall be included as part of the Operating Expenses. The Project may be included in a blanket policy (in which case the cost of such insurance allocable to the Project will be determined by Landlord based upon the
insurer’s cost calculations). Tenant shall also reimburse Landlord for any increased premiums or additional insurance which Landlord reasonably deems necessary as a result of Tenant’s use of the Premises. 

Tenant, at its sole cost and expense, shall maintain during the Term: all risk property insurance with business interruption and extra expense
coverage, covering the full replacement cost of all property and improvements installed or placed in the Premises by Tenant at Tenant’s expense; workers’ compensation insurance with no less than the minimum limits required by law;
employer’s liability insurance with such limits as required by law; and commercial general liability insurance, with a minimum limit of not less than $2,000,000 per occurrence for bodily injury and property damage with respect to the Premises.
The commercial general liability insurance policy shall name Alexandria Real Estate Equities, Inc., and Landlord, its officers, directors, employees, managers, agents, invitees and contractors (collectively, “Landlord Parties”), as
additional insureds; insure on an occurrence and not a claims-made basis; be issued by insurance companies which have a rating of not less than policyholder rating of A and financial category rating of at least Class X in “Best’s Insurance
Guide”; shall not be cancelable for nonpayment of premium unless 30 days prior written notice shall have been given to Landlord from the insurer; contain a hostile fire endorsement and a contractual liability endorsement; and provide primary
coverage to Landlord (any policy issued to Landlord providing duplicate or similar coverage shall be deemed excess over Tenant’s policies). Copies of such policies (if requested by Landlord), or certificates of insurance showing the limits of
coverage required hereunder and showing Landlord as an additional insured, along with reasonable evidence of the payment of premiums for the applicable period, shall be delivered to Landlord by Tenant upon commencement of the Term and upon each
renewal of said insurance. Tenant’s policy may be a “blanket policy” with an aggregate per location endorsement which specifically provides that the amount of insurance shall not be prejudiced by other losses covered by the policy.
Tenant shall, at least 5 days prior to the expiration of such policies, furnish Landlord with renewal certificates. 
 In each instance
where insurance is to name Landlord as an additional insured, Tenant shall upon written request of Landlord also designate and furnish certificates so evidencing Landlord as additional insured to: (i) any lender of Landlord holding a security
interest in the Project or any portion thereof, (ii) the landlord under any lease wherein Landlord is tenant of the real property on which the Project is located, if the interest of Landlord is or shall become that of a tenant under a ground or
other underlying lease rather than that of a fee owner, and/or (iii) any management company retained by Landlord to manage the Project. 

The property insurance obtained by Landlord and Tenant shall include a waiver of subrogation by the insurers and all rights based upon an
assignment from its insured, against Landlord or Tenant, and their respective officers, directors, employees, managers, agents, invitees and contractors (“Related Parties”), in connection with any loss or damage thereby insured
against. Neither party nor its respective Related Parties shall be liable to the other for loss or damage caused by any risk insured against under property insurance required to be maintained hereunder, and each party waives any claims against the
other party, and its respective Related Parties, for such loss or damage. The failure of a party to insure its property shall not void this waiver. Landlord and its respective Related Parties shall not be liable for, and


  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 14

  


Tenant hereby waives all claims against such parties for business interruption and losses occasioned thereby sustained by Tenant or any person claiming through Tenant resulting from any accident
or occurrence in or upon the Premises or the Project from any cause whatsoever. If the foregoing waivers shall contravene any law with respect to exculpatory agreements, the liability of Landlord or Tenant shall be deemed not released but shall be
secondary to the other’s insurer. 
 Landlord may require insurance policy limits to be raised to conform with requirements of
Landlord’s fender and/or to bring coverage limits to levels then being generally required of new tenants within the Project; provided, however, that the increased amount of coverage is consistent with coverage amounts then being required by
institutional owners of similar projects with tenants occupying similar size premises in the geographical area in which the Project is located. 

18. Restoration. lf, at any time during the Term, the Project or the Premises are damaged or destroyed by a fire or other insured
casualty. Landlord shall notify Tenant within 60 days after discovery of such damage as to the amount of time Landlord reasonably estimates it will take to restore the Project or the Premises, as applicable (the “Restoration
Period”). If the Restoration Period is estimated to exceed 12 months (the “Maximum Restoration Period”), Landlord may, in such notice, elect to terminate this Lease as of the date that is 75 days after the date of discovery
of such damage or destruction. Unless Landlord so elects to terminate this Lease. Landlord shall, subject to receipt of sufficient insurance proceeds (with any deductible to be treated as a current Operating Expense), promptly restore the Premises
(excluding the improvements installed by Tenant or by Landlord and paid for by Tenant), subject to delays arising from the collection of insurance proceeds, from Force Majeure events or as needed to obtain any license, clearance or other
authorization of any kind required to enter into and restore the Premises issued by any Governmental Authority having jurisdiction over the use, storage, handling, treatment, generation, release, disposal, removal or remediation of Hazardous
Materials (as defined in Section 30) in, on or about the Premises (collectively referred to herein as “Hazardous Materials Clearances”); provided, however, that if repair or restoration of the Premises is not
substantially complete as of the end of the Maximum Restoration Period or, if longer, the Restoration Period, Landlord may, in its sole and absolute discretion, elect not to proceed with such repair and restoration, in which event Landlord shall be
relieved of its obligation to make such repairs or restoration and this Lease shall terminate as of the date that is 75 days after the later of: (i)discovery of such damage or destruction, or (ii) the data all required Hazardous Materials
Clearances are obtained, but Landlord shall retain any Rent paid and the right to any Rent payable by Tenant prior to such election by Landlord or Tenant. 

Tenant, at its expense, shall promptly perform, subject to delays arising from the collection of insurance proceeds, from Force Majeure (as
defined in Section 34) events or to obtain Hazardous Material Clearances, all repairs or restoration not required to be done by Landlord. Notwithstanding the foregoing, either Landlord or Tenant may terminate this Lease upon written notice to
the other if the Premises are damaged during the last year of the Term and Landlord reasonably estimates that it will take more than 2 months to repair such damage, or if insurance proceeds are not available for such restoration. Rent shall be
abated from the date all required Hazardous Material Clearances are obtained until the Premises are repaired and restored, in the proportion which the area of the Premises, if any, which is not usable by Tenant bears to the total area of the
Premises, unless Landlord provides Tenant with other space during the period of repair that is suitable in Tenant’s commercially reasonable judgment for the temporary conduct of Tenant’s business. Such abatement shall be the sole remedy of
Tenant, and except as provided in this Section 18, Tenant waives any right to terminate the Lease by reason of damage or casualty loss. 

The provisions of this Lease, including this Section 18, constitute an express agreement between Landlord and Tenant with respect
to any and all damage to, or destruction of, all or any part of the Premises, or any other portion of the Project, and any statute or regulation which is now or may hereafter be in effect shall have no application to this Lease or any damage or
destruction to all or any part of the Premises or any other portion of the Project, the parties hereto expressly agreeing that this Section 18 sets forth their entire understanding and agreement with respect to such matters. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 15

  

19. Condemnation. If the whole or any material part of the Premises or the Project is taken for any public or quasi-public use under
governmental law, ordinance, or regulation, or by right of eminent domain, or by private purchase in lieu thereof (a “Taking” or “Taken”), and the Taking would in Landlord’s reasonable judgment, either prevent
or materially interfere with Tenant’s use of the Premises or materially interfere with or impair Landlord’s ownership or operation of the Project, then upon written notice by Landlord this Lease shall terminate and Rent shall be
apportioned as of said date. If part of the Premises shall be Taken, and this Lease is not terminated as provided above, Landlord shall promptly restore the Premises and the Project as nearly as is commercially reasonable under the circumstances to
their condition prior to such partial Taking and the rentable square footage of the Building, the rentable square footage of the Premises, Tenant’s Share of Operating Expenses and the Rent payable hereunder during the unexpired Term shall be
reduced to such extent as may be fair and reasonable under the circumstances. Upon any such Taking, Landlord shall be entitled to receive the entire price or award from any such Taking without any payment to Tenant, and Tenant hereby assigns to
Landlord Tenant’s interest, if any, in such award. Tenant shall have the right, to the extent that same shall not diminish Landlord’s award, to make a separate claim against the condemning authority (but not Landlord) for such compensation
as may be separately awarded or recoverable by Tenant for moving expenses and damage to Tenant’s trade fixtures, if a separate award for such items is made to Tenant. Tenant hereby waives any and all rights it might otherwise have pursuant to
any provision of state law to terminate this Lease upon a partial Taking of the Premises or the Project. 
 20. Events of Default.
Each of the following events shall be a default (“Default”) by Tenant under this Lease: 
 (a) Payment Defaults.
Tenant shall fail to pay any installment of Rent or any other payment hereunder when due; provided, however, that Landlord will give Tenant notice and an opportunity to cure any failure to pay Rent within 3 days of any such notice not more than once
in any 12 month period and Tenant agrees that such notice shall be in lieu of and not in addition to, or shall be deemed to be, any notice required by law. 

(b) Insurance. Any insurance required to be maintained by Tenant pursuant to this Lease shall be canceled or terminated or shall expire
or shall be reduced or materially changed, or Landlord shall receive a notice of nonrenewal of any such insurance and Tenant shall fail to obtain replacement insurance at least 20 days before the expiration of the current coverage. 

(c) Abandonment. Tenant shall abandon the Premises. 

(d) Improper Transfer. Tenant shall assign, sublease or otherwise transfer or attempt to transfer all or any portion of Tenant’s
interest in this Lease or the Premises except as expressly permitted herein, or Tenant’s interest in this Lease shall be attached, executed upon, or otherwise judicially seized and such action is not released within 90 days of the action. 

(e) Liens. Tenant shall fail to discharge or otherwise obtain the release of any lien placed upon the Premises in violation of this
Lease within 10 days after any such lien is filed against the Premises. 
 (f) Insolvency Events. Tenant or any guarantor or surety
of Tenant’s obligations hereunder shall: (A) make a general assignment for the benefit of creditors; (B) commence any case, proceeding or other action seeking to have an order for relief entered on its behalf as a debtor or to
adjudicate it a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of it or its debts or seeking appointment of a receiver, trustee, custodian or other similar official for it or for
all or of any substantial part of its property (collectively a “Proceeding for Relief”); (C) become the subject of any Proceeding for Relief which is not dismissed within 90 days of its filing or entry; or (D) die or
suffer a legal disability (if Tenant, guarantor, or surety is an individual) or be dissolved or otherwise fail to maintain its legal existence (if Tenant, guarantor or surety is a corporation, partnership or other entity). 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 16

  

(g) Estoppel Certificate or Subordination Agreement. Tenant fails to execute any document required from Tenant under Sections 23
or 27 within 5 days after a second notice requesting such document. 
 (h) Other Defaults. Tenant shall fail to comply with
any provision of this Lease other than those specifically referred to in this Section 20, and, except as otherwise expressly provided herein, such failure shall continue for a period of 30 days after written notice thereof from Landlord
to Tenant; provided that if the nature of Tenant’s default pursuant to this Section 20(h) is such that it cannot be cured by the payment of money and reasonably requires more than 30 days to cure, then Tenant shall not be deemed to
be in default if Tenant commences such cure within said 30 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no later than 45 days from the date of
Landlord’s notice. 
 Any notice given under Section 20(h) hereof shall: (i) specify the alleged default,
(ii) demand that Tenant cure such default, (iii) be in lieu of, and not in addition to, or shall be deemed to be, any notice required under any provision of applicable law, and (iv) not be deemed a forfeiture or a termination of this
Lease unless Landlord elects otherwise in such notice; provided that if the nature of Tenant’s default pursuant to Section 20(h) is such that it cannot be cured by the payment of money and reasonably requires more than 30
days to cure, than Tenant shall not be deemed to be in default if Tenant commences such cure within said 30 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no
later than 45 days from the date of Landlord’s notice. 
 21. Landlord’s Remedies. 

(a) Payment By Landlord; Interest. Upon a Default by Tenant hereunder, Landlord may, without waiving or releasing any obligation of
Tenant hereunder, make such payment or perform such act. All sums so paid or incurred by Landlord, together with interest thereon, from the date such sums were paid or incurred, at the annual rate equal to 12% per annum or the highest rate
permitted by law (the “Default Rate”), whichever is less, shall be payable to Landlord on demand as Additional Rent. Nothing herein shall be construed to create or impose a duty on Landlord to mitigate any damages resulting from
Tenant’s Default hereunder. 
 (b) Late Payment Rent. Late payment by Tenant to Landlord of Rent and other sums due will cause
Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult and impracticable to ascertain. Such costs include, but are not limited to, processing and accounting charges and late charges which may be
imposed on Landlord under any Mortgage covering the Premises. Therefore, if any installment of Rent due from Tenant is not received by Landlord within 5 days after the date such payment is due, Tenant shall pay to Landlord an additional sum equal to
6% of the overdue Rent as a late charge. Notwithstanding the foregoing, before assessing a late charge the first time in any calendar year, Landlord shall provide Tenant written notice of the delinquency and will waive the right if Tenant pays such
delinquency within 5 days thereafter. The parties agree that this late charge represents a fair and reasonable estimate of the costs Landlord will incur by reason of late payment by Tenant. In addition to the late charge, Rent not paid when due
shall bear interest at the Default Rate from the 5th day after the date due until paid. 
 (c) Remedies. Upon the occurrence of a
Default, Landlord, at its option, without further notice or demand to Tenant, shall have in addition to all other rights and remedies provided in this Lease, at law or in equity, the option to pursue any one or more of the following remedies, each
and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever. 
 (i) Terminate this Lease,
or at Landlord’s option, Tenant’s right to possession only, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so. Landlord may, without prejudice to any other remedy which it may have for
possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages
therefor; 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 17

  

(ii) Upon any termination of this Lease, whether pursuant to the foregoing Section 21(c)(i) or otherwise, Landlord
may recover from Tenant the following: 
 (A) The worth at the time of award of any unpaid rent which has been earned at the
time of such termination; plus 
 (B) The worth at the time of award of the amount by which the unpaid rent which would have
been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 

(C) The worth at the time of award of the amount by which the unpaid rent for the balance of the Term after the time of award
exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus 
 (D) Any other amount
necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including, but
not limited to, brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion there of for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant;
and 
 (E) At Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted
from time to time by applicable law. 
 The term “rent” as used in this Section 21 shall be deemed to be and to mean all sums
of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii) (A) and (B), above, the “worth at the time of award” shall be
computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of
San Francisco at the time of award plus 1%. 
 (iii) Landlord may continue this Lease in effect after Tenant’s Default
and recover rent as it becomes due (Landlord and Tenant hereby agreeing that Tenant has the right to sublet or assign hereunder, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease following a
Default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due. 

(iv) Whether or not Landlord elects to terminate this Lease following a Default by Tenant, Landlord shall have the right to
terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Tenant and affecting the Premises or may, in Landlord’s sole discretion, succeed to Tenant’s interest in such subleases,
licenses, concessions or arrangements. Upon Landlord’s election to succeed to Tenant’s interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no
further right to or interest in the rent or other consideration receivable thereunder. 
 (v) Independent of the exercise of
any other remedy of Landlord hereunder or under applicable law. Landlord may conduct an environmental test of the Premises as generally described in Section 30(d) hereof, at Tenant’s expense. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 18

  

(d) Effect of Exercise. Exercise by Landlord of any remedies hereunder or otherwise available shall not be deemed to be an acceptance of
surrender of the Premises and/or a termination of this Lease by Landlord, it being understood that such surrender and/or termination can be effected only by the express written agreement of Landlord and Tenant. Any law, usage, or custom to the
contrary notwithstanding. Landlord shall have the right at all times to enforce the provisions of this Lease in strict accordance with the terms hereof; and the failure of Landlord at any time to enforce its rights under this Lease strictly in
accordance with same shall not be construed as having created a custom in any way or manner contrary to the specific terms, provisions, and covenants of this Lease or as having modified the same and shall not be deemed a waiver of Landlord’s
right to enforce one or more of its rights in connection with any subsequent default. A receipt by Landlord of Rent or other payment with knowledge of the breach of any covenant hereof shall not be deemed a waiver of such breach, and no waiver by
Landlord of any provision of this Lease shall be deemed to have been made unless expressed in writing and signed by Landlord. To the greatest extent permitted by law. Tenant waives the service of notice of Landlord’s intention to re-enter,
re-take or otherwise obtain possession of the Premises as provided in any statute, or to institute legal proceedings to that end, and also waives all right of redemption in case Tenant shall be dispossessed by a judgment or by warrant of any court
or judge. Any reletting of the Premises or any portion thereof shall be on such terms and conditions as Landlord in its sole discretion may determine. Landlord shall not be liable for, nor shall Tenant’s obligations hereunder be diminished
because of, Landlord’s failure to relet the Premises or collect rent due in respect of such reletting or otherwise to mitigate any damages arising by reason of Tenant’s Default. 

22. Assignment and Subletting. 

(a) General Prohibition. Without Landlord’s prior written consent subject to and on the conditions described in this
Section 22, Tenant shall not, directly or indirectly, voluntarily or by operation of law, assign this Lease or sublease the Premises or any part thereof or mortgage, pledge, or hypothecate its leasehold interest or grant any concession
or license within the Premises, and any attempt to do any of the foregoing shall be void and of no effect. If Tenant is a corporation, partnership or limited liability company, the shares or other ownership interests thereof which are not actively
traded upon a stock exchange or in the over-the-counter market, a transfer or series of transfers whereby 25% or more of the issued and outstanding shares or other ownership interests of such corporation are, or voting control is, transferred (but
excepting transfers upon deaths of individual owners) from a person or persons or entity or entities which were owners thereof at time of execution of this Lease to persons or entities who were not owners of shares or other ownership interests of
the corporation, partnership or limited liability company at time of execution of this Lease, shall be deemed an assignment of this Lease requiring the consent of Landlord as provided in this Section 22. 

(b) Permitted Transfers. If Tenant desires to assign, sublease, hypothecate or otherwise transfer this Lease or sublet the Premises
other than pursuant to a Permitted Assignment (as defined below), then at least 15 business days, but not more than 45 business days, before the date Tenant desires the assignment or sublease to be effective (the “Assignment Date”),
Tenant shall give Landlord a notice (the “Assignment Notice”) containing such information about the proposed assignee or sublessee, including the proposed use of the Premises and any Hazardous Materials proposed to be used, stored
handled, treated, generated in or released or disposed of from the Premises, the Assignment Date, any relationship between Tenant and the proposed assignee or sublessee, and all material terms and conditions of the proposed assignment or sublease,
including a copy of any proposed assignment or sublease in its final form, and such other information as Landlord may deem reasonably necessary or appropriate to its consideration whether to grant its consent. Landlord may, by giving written notice
to Tenant within 15 business days after receipt of the Assignment Notice: (i) grant such consent, (ii) refuse such consent, in its reasonable discretion; or (iii) terminate this Lease with respect to the space described in the
Assignment Notice as of the Assignment Date (an “Assignment Termination”). Among other reasons, it shall be reasonable for Landlord to withhold its consent in any of these instances: (1) the proposed assignee or subtenant is a
governmental agency; (2) in Landlord’s reasonable judgment, the use of the Premises by the proposed assignee or subtenant would entail any alterations that would lessen the value of the leasehold improvements in the Premises, or would
require increased services by Landlord; (3) in Landlord’s reasonable judgment, the proposed assignee or subtenant is engaged in areas 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 19

  


of scientific research or other business concerns that are controversial; (4) in Landlord’s reasonable judgment, the proposed assignee or subtenant lacks the creditworthiness to support
the financial obligations it will incur under the proposed assignment or sublease; (5) in Landlord’s reasonable judgment, the character, reputation, or business of the proposed assignee or subtenant is inconsistent with the desired
tenant-mix or the quality of other tenancies in the Project or is inconsistent with the type and quality of the nature of the Building; (6) Landlord has received from any prior landlord to the proposed assignee or subtenant a negative report
concerning such prior landlord’s experience with the proposed assignee or subtenant; (7) Landlord has experienced previous defaults by or is in litigation with the proposed assignee or subtenant; (8) the use of the Premises by the
proposed assignee or subtenant will violate any applicable Legal Requirement; (9) the proposed assignee or subtenant is an entity with whom Landlord is negotiating to lease space in the Project; or (10) the assignment or sublease is
prohibited by Landlord’s lender. If Landlord delivers notice of its election to exercise an Assignment Termination, Tenant shall have the right to withdraw such Assignment Notice by written notice to Landlord of such election within 5 business
days after Landlord’s notice electing to exercise the Assignment Termination. If Tenant withdraws such Assignment Notice, this Lease shall continue in full force and effect. If Tenant does not withdraw such Assignment Notice, this Lease, and
the term and estate herein granted, shall terminate as of the Assignment Date with respect to the space described in such Assignment Notice. No failure of Landlord to exercise any such option to terminate this Lease, or to deliver a timely notice in
response to the Assignment Notice, shall be deemed to be Landlord’s consent to the proposed assignment, sublease or other transfer. Tenant shall pay to Landlord a fee equal to One Thousand Five Hundred Dollars ($1,500) in connection with its
consideration of any Assignment Notice and/or its preparation or review of any consent documents. Notwithstanding the foregoing. Landlord’s consent to an assignment of this Lease or a subletting of any portion of the Premises to any entity
controlling, controlled by or under common control with Tenant (a “Control Permitted Assignment”) shall not be required, provided that Landlord shall have the right to approve the form of any such sublease or assignment. In
addition, Tenant shall have the right to assign this Lease, upon 30 days prior written notice to Landlord (unless Tenant is prohibited from providing such notice by confidentiality or Legal Requirements in which case Tenant shall notify Landlord
promptly thereafter) but without obtaining Landlord’s prior written consent, to a corporation or other entity which is a successor-in-interest to Tenant, by way of merger, consolidation or corporate reorganization, or by the purchase of all or
substantially all of the assets or the ownership interests of Tenant provided that (i) such merger or consolidation, or such acquisition or assumption, as the case may be, is for a good business purpose and not principally for the purpose of
transferring the Lease, and (ii) the net worth (as determined in accordance with generally accepted accounting principles (“GAAP”)) of the assignee is not less than the greater of the net worth (as determined in accordance with
GAAP) of Tenant as of (A) the Commencement Date, or (B) as of the date of Tenant’s most current quarterly or annual financial statements, and (iii) such assignee shall agree in writing to assume all of the terms, covenants and
conditions of this Lease arising after the effective date of the assignment (a “Corporate Permitted Assignment”). Control Permitted Assignments and Corporate Permitted Assignments are hereinafter referred to as “Permitted
Assignments.” 
 (c) Additional Conditions. As a condition to any such assignment or subletting, whether or not
Landlord’s consent is required. Landlord may require: 
 (i) that any assignee or subtenant agree, in writing at the
time of such assignment or subletting, that if Landlord gives such party notice that Tenant is in default under this Lease, such party shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments will be received by
Landlord without any liability except to credit such payment against those due under the Lease, and any such third party shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided,
however, in no event shall Landlord or its successors or assigns be obligated to accept such attornment; and 
 (ii) A
list of Hazardous Materials, certified by the proposed assignee or sublessee to be true and correct, which the proposed assignee or sublessee intends to use, store, handle, treat, generate in or release or dispose of from the Premises, together with
copies of all documents relating to such use, storage, handling, treatment, generation, release or disposal of Hazardous Materials by the proposed assignee or subtenant in the Premises or on the Project,


  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 20

  


prior to the proposed assignment or subletting, including, without limitation: permits; approvals; reports and correspondence; storage and management plans; plans relating to the installation of
any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given its written consent to do so, which consent may be withheld in Landlord’s sole and absolute
discretion); and all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks. Neither Tenant nor any
such proposed assignee or subtenant is required, however, to provide Landlord with any portion(s) of the such documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials
or hazardous activities. The provisions of this cause (ii) shall not apply if the Proposed Use of the proposed assignee or sublicense is purely an office use at the time of the proposed assignment or sublease. 

(d) No Release of Tenant, Sharing of Excess Rents. Notwithstanding any assignment or subletting. Tenant and any guarantor or surety of
Tenant’s obligations under this Lease shall at all times remain fully and primarily responsible and liable for the payment of Rent and for compliance with all of Tenant’s other obligations under this Lease. If the Rent due and payable by a
sublessee or assignee (or a combination of the rental payable under such sublease or assignment plus any bonus or other consideration therefor or incident thereto in any form) exceeds the sum of the rental payable under this Lease, (excluding
however, any Rent payable under this Section) and actual and reasonable brokerage fees and costs related to and required pursuant to any such sublease (“Excess Rent”), then Tenant shall be bound and obligated to pay Landlord as
Additional Rent hereunder 50% of such Excess Rent within 10 days following receipt thereof by Tenant. If Tenant shall sublet the Premises or any part thereof. Tenant hereby immediately and irrevocably assigns to Landlord, as security for
Tenant’s obligations under this Lease, all rent from any such subletting, and Landlord as assignee and as attorney-in-fact for Tenant, or a receiver for Tenant appointed on Landlord’s application, may collect such rent and apply it toward
Tenant’s obligations under this Lease; except that, until the occurrence of a Default, Tenant shall have the right to collect such rent. 

(e) No Waiver. The consent by Landlord to an assignment or subletting shall not relieve Tenant or any assignees of this Lease or any
sublessees of the Premises from obtaining the consent of Landlord to any further assignment or subletting nor shall it release Tenant or any assignee or sublessee of Tenant from full and primary liability under the Lease. The acceptance of Rent
hereunder, or the acceptance of performance of any other term, covenant, or condition thereof, from any other person or entity shall not be deemed to be a waiver of any of the provisions of this Lease or a consent to any subletting, assignment or
other transfer of the Premises. 
 (f) Prior Conduct of Proposed Transferee. Notwithstanding any other provision of this
Section 22, if (i) the proposed assignee or sublessee of Tenant has been required by any prior landlord, lender or Governmental Authority to take remedial action in connection with Hazardous Materials contaminating a property, where the
contamination resulted from such party’s action or use of the property in question, (ii) the proposed assignee or sublessee is subject to an enforcement order issued by any Governmental Authority in connection with the use, storage,
handling, treatment, generation, release or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority), or (iii) because of the existence of a
pre-existing environmental condition in the vicinity of or underlying the Project, the risk that Landlord would be targeted as a responsible party in connection with the remediation of such pre-existing environmental condition would be materially
increased or exacerbated by the proposed use of Hazardous Materials by such proposed assignee or sublessee, Landlord shall have the absolute right to refuse to consent to any assignment or subletting to any such party. 

23. Estoppel Certificate. Tenant shall, within 10 business days of written notice from Landlord, execute, acknowledge and deliver a
statement in writing in any form reasonably requested by a proposed lender. or purchaser, (i) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this
Lease as no modified is in full force and effect) and the dates to which the rental and other charges are paid in advance, if any, (ii)

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 21

  


acknowledging that there are not any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (iii) setting forth such further information with
respect to the status of this Lease or the Premises as may be requested thereon. Any such statement may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the real property of which the Premises are a part.
Tenant’s failure to deliver such statement within such time shall, at the option of Landlord, constitute a Default under this Lease, and, in any event, shall be conclusive upon Tenant that the Lease is in full force and effect and without
modification except as may be represented by Landlord in any certificate prepared by Landlord and delivered to Tenant for execution. 
 24.
Quiet Enjoyment. So long as Tenant is not in Default under this Lease. Tenant shall, subject to the terms of this Lease, at all times during the Term, have peaceful and quiet enjoyment of the Premises against any person claiming by, through
or under Landlord. 
 25. Prorations. All prorations required or permitted to be made hereunder shall be made on the basis of a 360
day year and 30 day months. 
 26. Rules and Regulations. Tenant shall, at all times during the Term and any extension thereof,
comply with all reasonable rules and regulations at any time or from time to time established by Landlord covering use of the Premises and the Project. The current rules and regulations are attached hereto as Exhibit E. If there is any conflict
between said rules and regulations and other provisions of this Lease, the terms and provisions of this Lease shall control. Landlord shall not have any liability or obligation for the breach of any rules or regulations by other tenants in the
Project and shall not enforce such rules and regulations in a discriminatory manner. 
 27. Subordination. This Lease and
Tenant’s interest and rights hereunder are hereby made and shall be subject and subordinate at all times to the lien of any Mortgage now existing or hereafter created on or against the Project or the Premises, and all amendments, restatements,
renewals, modifications, consolidations, refinancing, assignments and extensions thereof, without the necessity of any further instrument or act on the part of Tenant; provided, however that so long as there is no Default hereunder,
Tenant’s right to possession of the Premises shall not be disturbed by the Holder of any such Mortgage. Tenant agrees, at the election of the Holder of any such Mortgage, to attorn to any such Holder. Tenant agrees upon demand to execute,
acknowledge and deliver such instruments, confirming such subordination, and such instruments of attornment as shall be requested by any such Holder, provided any such instruments contain appropriate non—disturbance provisions assuring
Tenant’s quiet enjoyment of the Premises as set forth in Section 24 hereof. Notwithstanding the foregoing, any such Holder may at any time subordinate its Mortgage to this Lease, without Tenant’s consent, by notice in writing
to Tenant, and thereupon this Lease shall be deemed prior to such Mortgage without regard to their respective dates of execution, delivery or recording and in that event such Holder shall have the same rights with respect to this Lease as though
this Lease had been executed prior to the execution, delivery and recording of such Mortgage and had been assigned to such Holder. The term “Mortgage” whenever used in this Lease shall be deemed to include deeds of trust, security
assignments and any other encumbrances, and any reference to the “Holder” of a Mortgage shall be deemed to include the beneficiary under a deed of trust. 

28. Surrender. Upon the expiration of the Term or earlier termination of Tenant’s right of possession. Tenant shall surrender the
Premises to Landlord in the same condition as received, reasonable wear and tear excepted, subject to any Alterations or Installations permitted by Landlord to remain in the Premises, free of Hazardous Materials brought upon, kept, used, stored,
handled, treated, generated in, or released or disposed of from, the Premises by any person other than a Landlord Party (collectively, “Tenant HazMat Operations”) and released of all Hazardous Materials Clearances, broom clean,
ordinary wear and tear and casualty loss and condemnation covered by Sections 18 and 19 excepted. At least 3 months prior to the surrender of the Premises. Tenant shall deliver to Landlord a narrative description of the actions
proposed (or required by any Governmental Authority) to be taken by Tenant in order to surrender the Premises (including any Installations permitted by Landlord to remain in the Premises) at the expiration or earlier termination of the Term, free
from any residual impact from the Tenant HazMat Operations and otherwise released for unrestricted use and occupancy (the “Surrender  

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 22

  


Plan”). Such Surrender Plan shall be accompanied by a current listing of (i) all Hazardous Materials licenses and permits held by or on behalf of any Tenant Party with respect to
the Premises, and (ii) all Hazardous Materials used, stored, handled, treated, generated, released or disposed of from the Premises, and shall be subject to the review and approval of Landlord’s environmental consultant. In connection with
the review and approval of the Surrender Plan, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such additional non-proprietary information concerning Tenant HazMat Operations as Landlord shall reasonably request. On
or before such surrender, Tenant shall deliver to Landlord evidence that the approved Surrender Plan shall have been satisfactorily completed and Landlord shall have the right, subject to reimbursement at Tenant’s expense as set forth below, to
cause Landlord’s environmental consultant to inspect the Premises and perform such additional procedures as may be deemed reasonably necessary to confirm that the Premises are, as of the effective date of such surrender or early termination of
the Lease, free from any residual impact from Tenant HazMat Operations. Tenant shall reimburse Landlord, as Additional Rent, for the actual out-of pocket expense incurred by Landlord for Landlord’s environmental consultant to review and approve
the Surrender Plan and to visit the Premises and verify satisfactory completion of the same, which cost shall not exceed $5,000. Landlord shall have the unrestricted right to deliver such Surrender Plan and any report by Landlord’s
environmental consultant with respect to the surrender of the Premises to third parties; provided, however, that Landlord instructs such parties to treat the same as confidential. 

If Tenant shall fail to prepare or submit a Surrender Plan approved by Landlord, or if Tenant shall fail to complete the approved Surrender
Plan, or if such Surrender Plan, whether or not approved by Landlord, shall fail to adequately address any residual effect of Tenant HazMat Operations in, on or about the Premises, Landlord shall have the right to take such actions as Landlord may
deem reasonable or appropriate to assure that the Premises and the Project are surrendered free from any residual impact from Tenant HazMat Operations, the cost of which actions shall be reimbursed by Tenant as Additional Rent, without regard to the
limitation set forth in the first paragraph of this Section 28. 
 Tenant shall immediately return to Landlord all keys and/or
access cards to parking, the Project, restrooms or all or any portion of the Premises furnished to or otherwise procured by Tenant. If any such access card or key is lost, Tenant shall pay to Landlord, at Landlord’s election, either the
reasonable cost of replacing such lost access card or key or the reasonable cost of reprogramming the access security system in which such access card was used or changing the lock or locks opened by such lost key. Any Tenant’s Property,
Alterations and property not so removed by Tenant as permitted or required herein shall be deemed abandoned and may be stored, removed, and disposed of by Landlord at Tenant’s expense, and Tenant waives all claims against Landlord for any
damages resulting from Landlord’s retention and/or disposition of such property. All obligations of Tenant hereunder not fully performed as of the termination of the Term, including the obligations of Tenant under Section 30 hereof,
shall survive the expiration or earlier termination of the Term, including, without limitation, indemnity obligations, payment obligations with respect to Rent and obligations concerning the condition and repair of the Premises. 

29. Waiver of Jury Trial. TO THE EXTENT PERMITTED BY LAW, TENANT AND LANDLORD WAIVE ANY RIGHT TO TRIAL BY JURY OR TO HAVE A JURY
PARTICIPATE IN RESOLVING ANY DISPUTE, WHETHER SOUNDING IN CONTRACT, TORT, OR OTHERWISE, BETWEEN LANDLORD AND TENANT ARISING OUT OF THIS LEASE OR ANY OTHER INSTRUMENT, DOCUMENT, OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION HEREWITH OR THE
TRANSACTIONS RELATED HERETO. 
 30. Environmental Requirements. 

(a) Prohibition/Compliance/Indemnity. Tenant shall not cause or permit any Hazardous Materials (as hereinafter defined) to be brought
upon, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises or the Project in violation of applicable Environmental Requirements (as hereinafter defined) by Tenant or any Tenant Party. If Tenant
breaches the obligation stated in the preceding sentence, or if the presence of Hazardous Materials in the Premises during the Term or any holding over results in contamination of the Premises, the Project or any adjacent property or if
contamination of the Premises, the Project or any adjacent property by Hazardous Materials 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 23

  


brought into, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises by anyone other than Landlord and Landlord’s employees, agents and
contractors otherwise occurs during the Term or any holding over. Tenant hereby indemnifies and shall defend and hold Landlord, its officers, directors, employees, agents and contractors harmless from any and all actions (including, without
limitation, remedial or enforcement actions of any kind, administrative or judicial proceedings, and orders or judgments arising out of or resulting therefrom), costs, claims, damages (including, without limitation, punitive damages and damages
based upon diminution in value of the Premises or the Project, or the loss of, or restriction on, use of the Premises or any portion of the Project), expenses (including, without limitation, attorneys’, consultants’ and experts’ fees,
court costs and amounts paid in settlement of any claims or actions), fines, forfeitures or other civil, administrative or criminal penalties, injunctive or other relief (whether or not based upon personal injury, property damage, or contamination
of, or adverse effects upon, the environment, water tables or natural resources), liabilities or losses (collectively, “Environmental Claims”) which arise during or after the Term as a result of such contamination. This
indemnification of Landlord by Tenant includes, without limitation, costs incurred in connection with any investigation of site conditions or any cleanup, treatment, remedial, removal, or restoration work required by any federal, state or local
Governmental Authority because of Hazardous Materials present in the air, soil or ground water above, on, or under the Premises. Without limiting the foregoing, if the presence of any Hazardous Materials on the Premises, the Building, the Project or
any adjacent property caused or permitted by Tenant or any Tenant Party results in any contamination of the Premises, the Building, the Project or any adjacent property. Tenant shall promptly take all actions at its sole expense and in accordance
with applicable Environmental Requirements as are necessary to return the Premises, the Building, the Project or any adjacent property to the condition existing prior to the time of such contamination, provided that Landlord’s approval of such
action shall first be obtained, which approval shall not unreasonably be withheld so long as such actions would not potentially have any material adverse long-term or short-term effect on the Premises, the Building or the Project. 

(b) Business. Landlord acknowledges that it is not the intent of this Section 30 to prohibit Tenant from using the Premises
for the Permitted Use. Tenant may operate its business according to prudent industry practices so long as the use or presence of Hazardous Materials is strictly and properly monitored according to all then applicable Environmental Requirements. As a
material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to deliver to Landlord prior to the Commencement Date a list identifying each type of Hazardous Materials to be brought upon,
kept, used, stored, handled, treated, generated on, or released or disposed of from, the Premises and setting forth any and all governmental approvals or permits required in connection with the presence, use, storage, handling, treatment,
generation, release or disposal of such Hazardous Materials on or from the Premises (“Hazardous Materials List”). Tenant shall deliver to Landlord an updated Hazardous Materials List at least once a year and shall also deliver an
updated list before any new type of Hazardous Material is brought onto, kept, used, stored, handled, treated, generated on, or released or disposed of from, the Premises. Tenant shall deliver to Landlord true and correct copies of the following
documents (the “Haz Mat Documents”) relating to the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials prior to the Commencement Date, or if unavailable at that time, concurrent with the
receipt from or submission to a Governmental Authority: permits; approvals; reports and correspondence; storage and management plans, notice of violations of any Legal Requirements; plans relating to the installation of any storage tanks to be
installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent may be withheld in Landlord’s sole and absolute discretion); all closure
plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks; and a Surrender Plan (to the extent surrender in
accordance with Section 28 cannot be accomplished in 3 months). Tenant is not required, however, to provide Landlord with any portion(s) of the Haz Mat Documents containing information of a proprietary nature which, in and of themselves,
do not contain a reference to any Hazardous Materials or hazardous activities. It is not the intent of this Section to provide Landlord with information which could be detrimental to Tenant’s business should such information become possessed by
Tenant’s competitors. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 24

  

(c) Tenant Representation and Warranty. Tenant hereby represents and warrants to Landlord that (i) neither Tenant nor, to the best
of Tenant’s knowledge, any of its legal predecessors has been required by any prior landlord, lender or Governmental Authority at any time to take remedial action in connection with Hazardous Materials contaminating a property which
contamination was permitted by Tenant of such predecessor or resulted from Tenant’s or such predecessor’s action or use of the property in question, and (ii) Tenant is not subject to any enforcement order issued by any Governmental
Authority in connection with the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority).
If Landlord determines that this representation and warranty was not true as of the date of this lease. Landlord shall have the right to terminate this Lease in Landlord’s sole and absolute discretion. 

(d) Testing. Landlord shall have the right to conduct annual tests of the Premises to determine whether any contamination of the
Premises or the Project has occurred as a result of Tenant’s use. Tenant shall be required to pay the cost of such annual test of the Premises if there is violation of this Section 30 or if contamination for which Tenant is responsible
under this Section 30 is identified; provided, however, that if Tenant conducts its own tests of the Premises using third party contractors and test procedures acceptable to Landlord which tests are certified to Landlord. Landlord shall
accept such tests in lieu of the annual tests to be paid for by Tenant. In addition, at any time, and from time to time, prior to the expiration or earlier termination of the Term. Landlord shall have the right to conduct appropriate tests of the
Premises and the Project to determine if contamination has occurred as a result of Tenant’s use of the Premises. In connection with such testing, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such
non-proprietary information concerning the use of Hazardous Materials in or about the Premises by Tenant or any Tenant Party. If contamination has occurred for which Tenant is liable under this Section 30, Tenant shall pay all costs to conduct
such tests. If no such contamination is found, Landlord shall pay the costs of such tests (which shall not constitute an Operating Expense). Landlord shall provide Tenant with a copy of all third party, non-confidential reports and tests of the
Premises made by or on behalf of Landlord during the Term without representation or warranty and subject to a confidentiality agreement. Tenant shall, at its sole cost and expense, promptly and satisfactorily remediate any environmental conditions
identified by such testing for which Tenant is responsible under this Section 30 in accordance with all Environmental Requirements. Landlord’s receipt of or satisfaction with any environmental assessment in no way waives any rights which
Landlord may have against Tenant. 
 (e) Control Areas. Tenant shall be allowed to utilize up to its pro rata share of the Hazardous
Materials inventory within any control area or zone (located within the Premises), as designated by the applicable building code, for chemical use or storage. As used in the preceding sentence. Tenant’s pro rata share of any control areas or
zones located within the Premises shall be determined based on the rentable square footage that Tenant leases within the applicable control area or zone. For purposes of example only, if a control area or zone contains 10,000 rentable square feet
and 2,000 rentable square feet of a tenant’s premises are located within such control area or zone (while such premises as a whole contains 5,000 rentable square feet), the applicable tenant’s pro rata share of such control area would be
20%. 
 (f) Underground Tanks. If underground or other storage tanks storing Hazardous Materials located on the Premises or the
Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant. Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks. maintain appropriate records, obtain and maintain appropriate
insurance, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter
be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks. 

(g) Tenant’s Obligations. Tenant’s obligations under this Section 30 shall survive the expiration or earlier
termination of the Lease. During any period of time after the expiration or earlier termination of this Lease required by Tenant or Landlord to complete the removal from the Premises of 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 25

  


any Hazardous Materials (including, without limitation, the release and termination of any licenses or permits restricting the use of the Premises and the completion of the approved Surrender
Plan), Tenant shall continue to pay the full Rent in accordance with this Lease for any portion of the Premises that cannot be relet by Landlord due to Tenant’s failure to complete such removal of Hazardous Materials, which Rent shall be
prorated daily. 
 (h) Definitions. As used herein, the term “Environmental Requirements” means all applicable
present and future statutes, regulations, ordinances, rules, codes, judgments, orders or other similar enactments of any Governmental Authority regulating or relating to health, safety, or environmental conditions on, under, or about the Premises or
the Project, or the environment, including without limitation, the following: the Comprehensive Environmental Response, Compensation and Liability Act; the Resource Conservation and Recovery Act; and all state and local counterparts thereto, and any
regulations or policies promulgated or issued thereunder. As used herein, the term “Hazardous Materials” means and includes any substance, material, waste, pollutant, or contaminant listed or defined as hazardous or toxic, or
regulated by reason of its impact or potential impact on humans, animals and/or the environment under any Environmental Requirements, asbestos and petroleum, including crude oil or any fraction thereof, natural gas liquids, liquefied natural gas, or
synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas). As defined in Environmental Requirements, Tenant is and shall be deemed to be the “operator” of Tenant’s “facility” and the
“owner” of all Hazardous Materials brought on the Premises by Tenant or any Tenant Party, and the wastes, by-products, or residues generated, resulting, or produced therefrom. 

31. Tenant’s Remedies/Limitation of Liability. Landlord shall not be in default hereunder unless Landlord fails to perform any of
its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is
reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and
Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided
Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise
expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder. 
 All
obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the
Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each
new owner for the duration of such owner’s ownership. 
 32. Inspection and Access. Landlord and its agents, representatives,
and contractors may enter the Premises at any reasonable time to inspect the Premises and to make such repairs as may be required or permitted pursuant to this Lease and for any other business purpose. Landlord and Landlord’s representatives
may enter the Premises during business hours on not less than 48 hours advance written notice (except in the case of emergencies in which case no such notice shall be required and such entry may be at any time) for the purpose of effecting any such
repairs, inspecting the Premises, showing the Premises to prospective purchasers and, during the last year of the Term, to prospective tenants or for any other business purpose. Landlord may erect a suitable sign on the Premises stating the Premises
are available to let or that the Project is available for sale. Landlord may grant easements, make public dedications, designate Common Areas and create restrictions on or about the Premises, provided that no such easement, dedication, designation
or restriction materially, adversely affects Tenant’s use or occupancy of the Premises for the Permitted Use. At Landlord’s request, Tenant shall execute such instruments as may be necessary for such easements, dedications or restrictions,
provided that such items do not impose any financial or other material burden on Tenant. Tenant shall at all times, except in 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 26

  


the case of emergencies, have the right to escort Landlord or its agents, representatives, contractors or guests while the same are in the Premises, provided such escort does not materially and
adversely affect Landlord’s access rights hereunder. 
 33. Security. Tenant acknowledges and agrees that security devices and
services, if any, while intended to deter crime may not in given instances prevent theft or other criminal acts and that Landlord is not providing any security services with respect to the Premises. Tenant agrees that Landlord shall not be liable to
Tenant for, and Tenant waives any claim against Landlord with respect to, any loss by theft or any other damage suffered or incurred by Tenant in connection with any unauthorized entry into the Premises or any other breach of security with respect
to the Premises. Tenant shall be solely responsible for the personal safety of Tenant’s officers, employees, agents, contractors, guests and invitees while any such person is in, on or about the Premises and/or the Project. Tenant shall at
Tenant’s cost obtain insurance coverage to the extent Tenant desires protection against such criminal acts. 
 34. Force
Majeure. Landlord shall not be responsible or liable for delays in the performance of its obligations hereunder when caused by, related to, or arising out of acts of God, sinkholes or subsidence, strikes, lockouts, or other labor disputes,
embargoes, quarantines, weather, national, regional, or local disasters, calamities, or catastrophes, inability to obtain labor or materials (or reasonable substitutes therefor) at reasonable costs or failure of, or inability to obtain, utilities
necessary for performance, governmental restrictions, orders, limitations, regulations, or controls, national emergencies, delay in issuance or revocation of permits, enemy or hostile governmental action, terrorism, insurrection, riots, civil
disturbance or commotion, fire or other casualty, and other causes or events beyond the reasonable control of Landlord (“Force Majeure”). 

35. Brokers. Landlord and Tenant each represents and warrants that it has not dealt with any broker, agent or other person
(collectively, “Broker”) in connection with this transaction and that no Broker brought about this transaction, other than CRESA Partners and Jones Lang LaSalle. Landlord and Tenant each hereby agree to indemnify and hold the other
harmless from and against any claims by any Broker, other than the broker, if any named in this Section 35, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard
to this leasing transaction. Landlord shall pay any commission due to the brokers named in this Section 35 pursuant to separate written agreements between Landlord, on the one hand, and CRESA Partners and Jones Lang LaSalle,
respectively, on the other hand. 
 36. Limitation on Landlord’s Liability. NOTWITHSTANDING ANYTHING SET FORTH HEREIN OR IN ANY
OTHER AGREEMENT BETWEEN LANDLORD AND TENANT TO THE CONTRARY: (A) LANDLORD SHALL NOT BE LIABLE TO TENANT OR ANY OTHER PERSON FOR (AND TENANT AND EACH SUCH OTHER PERSON ASSUME ALL RISK OF) LOSS, DAMAGE OR INJURY, WHETHER ACTUAL OR CONSEQUENTIAL
TO: TENANT’S PERSONAL PROPERTY OF EVERY KIND AND DESCRIPTION, INCLUDING, WITHOUT LIMITATION TRADE FIXTURES, EQUIPMENT, INVENTORY, SCIENTIFIC RESEARCH, SCIENTIFIC EXPERIMENTS, LABORATORY ANIMALS, PRODUCT, SPECIMENS, SAMPLES, AND/OR SCIENTIFIC,
BUSINESS, ACCOUNTING AND OTHER RECORDS OF EVERY KIND AND DESCRIPTION KEPT AT THE PREMISES AND ANY AND ALL INCOME DERIVED OR DERIVABLE THEREFROM; (B) THERE SHALL BE NO PERSONAL RECOURSE TO LANDLORD FOR ANY ACT OR OCCURRENCE IN, ON OR ABOUT THE
PREMISES OR ARISING IN ANY WAY UNDER THIS LEASE OR ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT WITH RESPECT TO THE SUBJECT MATTER HEREOF AND ANY LIABILITY OF LANDLORD HEREUNDER SHALL BE STRICTLY LIMITED SOLELY TO LANDLORD’S INTEREST IN THE
PROJECT OR ANY PROCEEDS FROM SALE OR CONDEMNATION THEREOF AND ANY INSURANCE PROCEEDS PAYABLE IN RESPECT OF LANDLORD’S INTEREST IN THE PROJECT OR IN CONNECTION WITH ANY SUCH LOSS; AND (C) IN NO EVENT SHALL ANY PERSONAL LIABILITY BE ASSERTED
AGAINST LANDLORD IN CONNECTION WITH THIS LEASE NOR SHALL ANY RECOURSE BE HAD TO ANY OTHER PROPERTY OR ASSETS OF LANDLORD OR ANY OF LANDLORD’S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS. UNDER NO CIRCUMSTANCES SHALL LANDLORD OR ANY OF
LANDLORD’S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS BE LIABLE FOR INJURY TO TENANT’S BUSINESS OR FOR ANY LOSS OF INCOME OR PROFIT THEREFROM. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 27

  

37. Severability. If any clause or provision of this Lease is illegal, invalid or unenforceable under present or future laws, then and
in that event, it is the intention of the parties hereto that the remainder of this Lease shall not be affected thereby. It is also the intention of the parties to this Lease that in lieu of each clause or provision of this Lease that is illegal,
invalid or unenforceable, there be added, as a part of this Lease, a clause or provision as similar in effect to such illegal, invalid or unenforceable clause or provision as shall be legal, valid and enforceable. 

38. Signs; Exterior Appearance. Tenant shall not, without the prior written consent of Landlord, which may be granted or withheld in
Landlord’s sole discretion: (i) attach any awnings, exterior lights, decorations, balloons, flags, pennants, banners, painting or other projection to any outside wall of the Project, (ii) use any curtains, blinds, shades or screens
other than Landlord’s standard window coverings, (iii) coat or otherwise sunscreen the interior or exterior of any windows, (iv) place any bottles, parcels, or other articles on the window sills, (v) place any equipment,
furniture or other items of personal property on any exterior balcony, or (vi) paint, affix or exhibit on any part of the Premises or the Project any signs, notices, window or door lettering, placards, decorations, or advertising media of any
type which can be viewed from the exterior of the Premises. Interior signs on doors and the directory tablet shall be inscribed, painted or affixed for Tenant by Landlord at Landlord’s cost, and shall be of a size, color and type acceptable to
Landlord. Nothing may be placed on the exterior of corridor walls or corridor doors other than Landlord’s standard lettering. The directory tablet shall be provided exclusively for the display of the name and location of tenants. 

39. Right to Extend Term. Tenant shall have the right to extend the Term of the Lease upon the following terms and conditions: 

(a) Extension Right. Tenant shall have 1 right (an “Extension Right”) to extend the term of this Lease for 2 years (an
“Extension Term”) on the same terms and conditions as this Lease (other than with respect to Base Rent and the Work Letter) by giving Landlord written notice of its election to exercise the Extension Right at least 9 months prior to the
expiration of the Base Term of the Lease. 
 Base Rent shall be increased to $3.00 per rentable square foot of the Premises per month on the
commencement date of the Extension Term and shall be further increased to $3.10 per rentable square foot of the Premises per month on the first anniversary of the commencement of the Extension Term. 

(b) Rights Personal. The Extension Right is personal to Tenant and is not assignable without Landlord’s consent, which may be
granted or withheld in Landlord’s sole discretion separate and apart from any consent by Landlord to an assignment of Tenant’s interest in the Lease, except that it may be assigned in connection with any Permitted Assignment of this Lease.

 (c) Exceptions. Notwithstanding anything set forth above to the contrary, the Extension Right shall, at Landlord’s option,
not be in effect and Tenant may not exercise the Extension Right: 
 (i) during any period of time that Tenant is in Default
under any provision of this Lease; or 
 (ii) if Tenant has been in Default under any provision of this Lease 3 or more
times, whether or not the Defaults are cured, during the 12 month period immediately prior to the date that Tenant intends to exercise the Extension Right, whether or not the Defaults are cured. 

(d) No Extensions. The period of time within which the Extension Right may be exercised shall not be extended or enlarged by reason of
Tenant’s inability to exercise the Extension Right. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 28

  

(e) Termination. The Extension Right shall, at Landlord’s option, terminate and be of no further force or effect even after
Tenant’s due and timely exercise of the Extension Right, if, after such exercise, but prior to the commencement date of the Extension Term, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has
Defaulted 3 or more times during the period from the date of the exercise of the Extension Right to the date of the commencement of the Extension Term, whether or not such Defaults are cured. 

40. Miscellaneous. 
 (a)
Notices. All notices or other communications between the parties shall be in writing and shall be deemed duly given upon delivery or refusal to accept delivery by the addressee thereof if delivered in person, or upon actual receipt if
delivered by reputable overnight guaranty courier, addressed and sent to the parties at their addresses set forth above. Landlord and Tenant may from time to time by written notice to the other designate another address for receipt of future
notices. 
 (b) Joint and Several Liability. If and when included within the term “Tenant,” as used in this
instrument, there is more than one person or entity, each shall be jointly and severally liable for the obligations of Tenant. 
 (c)
Financial Information. Tenant shall furnish Landlord with true and complete copies of (i) Tenant’s most recent audited annual financial statements within 90 days of the end of each of Tenant’s fiscal years during the Term,
(ii) Tenant’s most recent unaudited quarterly financial statements within 45 days of the end of each of Tenant’s first three fiscal quarters of each of Tenant’s fiscal years during the Term, (iii) at Landlord’s request
from time to time, updated business plans, including cash flow projections and/or pro forma balance sheets and income statements, all of which shall be treated by Landlord as confidential information belonging to Tenant, (iv) corporate
brochures and/or profiles prepared by Tenant for prospective investors, and (v) any other financial information or summaries that Tenant typically provides to its lenders or shareholders. 

(d) Recordation. Neither this Lease nor a memorandum of lease shall be filed by or on behalf of Tenant in any public record. Landlord
may prepare and file, and upon request by Landlord Tenant will execute, a memorandum of lease. 
 (e) Interpretation. The normal rule
of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Lease or any exhibits or amendments hereto. Words of any gender used in this Lease shall be held and
construed to include any other gender, and words in the singular number shall be held to include the plural, unless the context otherwise requires. The captions inserted in this Lease are for convenience only and in no way define, limit or otherwise
describe the scope or intent of this Lease, or any provision hereof, or in any way affect the interpretation of this Lease. 
 (f) Not
Binding Until Executed. The submission by Landlord to Tenant of this Lease shall have no binding force or effect, shall not constitute an option for the leasing of the Premises, nor confer any right or impose any obligations upon either party
until execution of this Lease by both parties. 
 (g) Limitations on Interest. It is expressly the intent of Landlord and Tenant at
all times to comply with applicable law governing the maximum rate or amount of any interest payable on or in connection with this Lease. If applicable law is ever judicially interpreted so as to render usurious any interest called for under this
Lease, or contracted for, charged, taken, reserved, or received with respect to this Lease, then it is Landlord’s and Tenant’s express intent that all excess amounts theretofore collected by Landlord be credited on the applicable
obligation (or, if the obligation has been or would thereby be paid in full, refunded to Tenant), and the provisions of this Lease immediately shall be deemed reformed and the amounts thereafter collectible hereunder reduced, without the necessity
of the execution of any new document, so as to comply with the applicable law, but so as to permit the recovery of the fullest amount otherwise called for hereunder. 

  
 



 










			
	Net Multi-Tenant Laboratory	  	343 Oyster/Calithera – Page 29

  

(h) Choice of Law. Construction and interpretation of this Lease shall be governed by the internal laws of the state in which the
Premises are located, excluding any principles of conflicts of laws. 
 (i) Time. Time is of the essence as to the performance of
Tenant’s obligations under this Lease. 
 (j) OFAC. Tenant, and all beneficial owners of Tenant, are currently (a) in
compliance with and shall at all times during the Term of this Lease remain in compliance with the regulations of the Office of Foreign Assets Control (“OFAC”) of the U.S. Department of Treasury and any statute, executive order, or
regulation relating thereto (collectively, the “OFAC Rules”), (b) not listed on, and shall not during the term of this Lease be listed on, the Specially Designated Nationals and Blocked Persons List maintained by OFAC and/or on
any other similar list maintained by OFAC or other governmental authority pursuant to any authorizing statute, executive order, or regulation, and (c) not a person or entity with whom a U.S. person is prohibited from conducting business under
the OFAC Rules. 
 (k) Incorporation by Reference. All exhibits and addenda attached hereto are hereby incorporated into this Lease
and made a part hereof. If there is any conflict between such exhibits or addenda and the terms of this Lease, such exhibits or addenda shall control. 

(l) Entire Agreement. This Lease, including the exhibits attached hereto, constitutes the entire agreement between Landlord and Tenant
pertaining to the subject matter hereof and supersedes all prior and contemporaneous agreements, understandings, letters of intent, negotiations and discussions, whether oral or written, of the parties, and there are no warranties, representations
or other agreements, express or implied, made to either party by the other party in connection with the subject matter hereof except as specifically set forth herein. 

(m) No Accord and Satisfaction. No payment by Tenant or receipt by Landlord of a lesser amount than the monthly installment of Base
Rent or any Additional Rent will be other than on account of the earliest stipulated Base Rent and Additional Rent, nor will any endorsement or statement on any check or letter accompanying a check for payment of any Base Rent or Additional Rent be
an accord and satisfaction. Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance of such Rent or to pursue any other remedy provided in this Lease. 

(n) Hazardous Activities. Notwithstanding any other provision of this Lease, Landlord, for itself and its employees, agents and
contractors, reserves the right to refuse to perform any repairs or services in any portion of the Premises which, pursuant to Tenant’s routine safety guidelines, practices or custom or prudent industry practices, require any form of protective
clothing or equipment other than safety glasses. In any such case, Tenant shall contract with parties who are acceptable to Landlord, in Landlord’s reasonable discretion, for all such repairs and services, and Landlord shall, to the extent
required, equitably adjust Tenant’s Share of Operating Expenses in respect of such repairs or services to reflect that Landlord is not providing such repairs or services to Tenant. 

[ Signatures on next page ] 

  
 



 









 IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of the day and year first
above written. 
  

									
		  	TENANT:
		
		  	CALITHERA BIOSCIENCES, INC.,
		  	a Delaware corporation
			
		  	By:	  	 /s/ Susan Molineaux, Ph.d.

		  	Its:	  	 President & CEO

		
		  	LANDLORD:
		
		  	 ARE-TECHNOLOGY CENTER SSF, LLC,

a Delaware limited liability company

			
		  	By:	  	ALEXANDRIA REAL ESTATE EQUITIES, L.P.,
		  		  	a Delaware limited partnership,
		  		  	managing member
				
		  		  	By:	  	ARE-QRS CORP.,
		  		  		  	a Maryland corporation,
		  		  		  	general partner,
					
		  		  		  	By:	  	 /s/ Eric S. Johnson

		  		  		  	Its:	  	 Vice President

		  		  		  		  	 Real Estate Legal Affairs



  
 



 










			
		  	343 Oyster/Calithera – Page 1

  

EXHIBIT A TO LEASE 

DESCRIPTION OF PREMISES 
  

 
 



 

  
 



 










			
		  	343 Oyster/Calithera – Page 1

  

EXHIBIT B TO LEASE 

DESCRIPTION OF PROJECT 
 The land
referred to in this policy is situated in the State of California, County of San Mateo, City of South San Francisco and is described as follows: 

PARCEL I: 
 Parcel A, as shown on that certain
Parcel Map entitled, PARCEL MAP NO. 98 033” filed for Record on December 30, 1998 in Book 71 of Parcel Maps at Pages 13 and 14, Series No. 98222035, San Mateo County Records. 

PARCEL II: 
 Ingress, Egress and Public Utilities

 Affects: A non-exclusive easement for ingress, egress and utility purposes in, on, over, under and along all that certain real property situate in the
City South San Francisco, County of San Mateo, State of California, being over a portion of Parcel l as said Parcel 1 is shown on that certain Parcel Map, filed for record on November 12, 1973 in Book 22 of Parcel Maps at Page 45, San Mateo
County Records; said easement being more particularly described as follows: 
 BEGINNING at the Southwest corner of said Parcel 1; thence from said Point of
Beginning Northerly along the Westerly line of said Parcel 1 the following courses; North 0° 00’ 55” West 632.44 feet, South 89° 59’ 05” West 10.00 feet and North 0° 00’ 55” West 112.00 feet to a point
thereon; thence leaving last said line North 89° 59’ 05” East 25.00 feet; thence South 0° 00’ 55” East 743.67 feet to a point on the general Southerly line of said Parcel l; thence Westerly along last line South 87°
03’ 05” West 15.02 feet to the Point of Beginning. 
 PARCEL III 

Ingress and Egress 
 Affects: A non-exclusive easement for
ingress, egress, purposes in, on, over, under and along all that certain property situated in the City of south San Francisco, County of San Mateo, State of California being a portion of Parcel 1, as said Parcel 1 is shown on that certain Parcel
Map, filed for record on November 12, 1973 in Book 22 of Parcel Maps at Page 45, San Mateo County Records; said easement being over a strip of land 30.00 feet in width lying Westerly of and immediately adjacent to the following described
Easterly line thereof. 

  
 



 










			
		  	343 Oyster/Calithera – Page 2

  

BEGINNING at the Northeast corner of said Parcel 1; then from said Point of Beginning Southeasterly along the general Easterly line of said Parcel 1 the
following courses. South 0° 00’ 55” East 365.43 feet, tangent to the proceeding course along the arc of curve to the left having a radius of 85.00 feet and central angle of 20° 29’ 29”. an arc distance of 30.40 feet,
tangent to the proceeding curve South 20° 30’ 24” East 137.30 feet, tangent to the proceeding course along the arc of a curve to the left having a radius of 85.00 feet and a central angle of 39° 30’ 31”, an arc distance
of 58.61 feet, tangent to the proceeding curve South 60° 00’ 55” East 66.36 feet, tangent to the proceeding course along the arc of a curve to the right having a radius of 115.00 feet and a central angle of 60” 00’ 00”.
an arc distance of 120.43 feet and tangent to the proceeding curve South 0° 00’ 55” East 73.76 feet to the southeast corner of said Parcel 1, last said point being also the Southerly terminus of the easement described herein, said
easement being contiguous for its full width at its Northerly terminus to the Northerly line of said Parcel 1 and at its Southerly terminus to the southerly line of said Parcel 1. 

PARCEL IV: 
 Slope Easement 

Affects: A non-exclusive easement for slope purposes in, on, over, under and along all that certain real property situate in the City of South San Francisco,
County of San Mateo, State of California; said easement being over a portion of Parcel 3, as said Parcel is shown on that certain Parcel Map filed for record on January 15, 1974 in Book 23 of Parcel Map at Page 27, San Mateo County Records;
said easement being more particularly described as follows: 
 BEGINNING at a point on the general Northerly line of said Parcel 3, distant thereon North
89° 59 05” East 25.00 feet from the Northwesterly corner thereof; thence from said Point of Beginning Easterly along the Northerly line of said Parcel 3 North 89° 59’ 05” East 21.00 feet to a point thereon; thence leaving last
said line South 08° 35’ 00” East 13.00 feet; thence tangent to the preceding course along the arc of a curve to the left having a radius of 60.00 feet and a central angle of 67° 42’ 23” an arc distance of 70.90 feet;
thence Southerly along a line being parallel with and perpendicularly distant 93.03 feet Easterly from the Westerly line of said Parcel 3; then South 0° 00’ 55” East 21.74 feet; thence South 89° 59’ 05” West 68.03 feet;
thence North 0° 00’ 55” West 83.94 feet to the Point of Beginning. 
 EXCEPTING THEREFROM any portion lying within Parcel I of Parcels II, III
and IV. 

  
 



 










			
	Work Letter – Landlord Build	  	343 Oyster/Calithera – Page 1

  

EXHIBIT C TO LEASE 

WORK LETTER 
 THIS
WORK LETTER dated February 27, 2013 (this “Work Letter”) is made and entered into by and between ARE-TECHNOLOGY CENTER SSF, LLC, a Delaware limited liability company (“Landlord”), and CALITHERA
BIOSCIENCES, INC., a Delaware corporation (“Tenant”), and is attached to and made a part of the Lease Agreement dated February 14, 2013 (the “Lease”), by and between Landlord and Tenant. Any initially
capitalized terms used but not defined herein shall have the meanings given them in the Lease. 
 1. General Requirements.

 (a) Tenant’s Authorized Representative. Tenant designates Mark Bennett (“Tenant’s Representative”) as
the only person authorized to act for Tenant pursuant to this Work Letter. Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (“Communication”) from or on behalf of Tenant
in connection with this Work Letter unless such Communication is in writing from Tenant’s Representative. Tenant may change Tenant’s Representative at any time upon not less than 5 business days advance written notice to Landlord. Neither
Tenant nor Tenant’s Representative shall be authorized to direct Landlord’s contractors in the performance of Landlord’s Work (as hereinafter defined). 

(b) Landlord’s Authorized Representative. Landlord designates Rob Kain and Todd Miller (either such individual acting alone,
“Landlord’s Representative”) as the only persons authorized to act for Landlord pursuant to this Work Letter. Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or
on behalf of Landlord in connection with this Work Letter unless such Communication is in writing from Landlord’s Representative. Landlord may change either Landlord’s Representative at any time upon not less than 5 business days advance
written notice to Tenant. Landlord’s Representative shall be the sole persons authorized to direct Landlord’s contractors in the performance of Landlord’s Work. 

(c) Architects, Consultants and Contractors. Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and
any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI
Architect”) for the Tenant Improvements. 
 2. Tenant Improvements. 

(a) Tenant Improvements Defined. As used herein, “Tenant Improvements” shall mean all improvements to the Project of a
fixed and permanent nature as shown on the approved Tl Construction Drawings, as defined in Section 2(c) below. Other than Landlord’s Work (as defined in Section 3(a) below, Landlord shall not have any obligation
whatsoever with respect to the finishing of the Premises for Tenant’s use and occupancy. 
 (b) Tenant’s Space Plans.
Landlord and Tenant acknowledge and agree that the plan prepared by the Tl Architect attached hereto as Schedule 1 (the “Space Plan”) and the scope of work attached hereto as Schedule 2 have been approved by both
Landlord and Tenant. Tenant shall be solely responsible for all costs incurred by Landlord to alter the Building (or Landlord’s plans for the Building) as a result of Tenant’s requested changes. 

(c) Working Drawings. Not later than 20 days following the approval of the Space Plan, Landlord shall cause the Tl Architect to prepare
and deliver to Tenant for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which Tl Construction Drawings shall be prepared substantially in accordance with
the 

  
 



 










			
		  	343 Oyster/Calithera – Page 2

  


Space Plan. Tenant shall be solely responsible for ensuring that the Tl Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Tenant shall deliver its written
comments on the Tl Construction Drawings to Landlord not later than 10 business days after Tenant’s receipt of the same; provided, however, that Tenant may not disapprove any matter that is consistent with the Space Plan without submitting a
Change Request. Landlord and the Tl Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Tenant how Landlord proposes to respond to such comments, but Tenant’s review rights pursuant
to the foregoing sentence shall not delay the design or construction schedule for the Tenant Improvements. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design
reflected in the Tl Construction Drawings is consistent with the Space Plan, Tenant shall approve the Tl Construction Drawings submitted by Landlord, unless Tenant submits a Change Request. Once approved by Tenant, subject to the provisions of
Section 4 below, Landlord shall not materially modify the Tl Construction Drawings except as may be reasonably required in connection with the issuance of the Tl Permit (as defined in Section 3(b) below). 

(d) Approval and Completion. It is hereby acknowledged by Landlord and Tenant that the Tl Construction Drawings must be completed and
approved not later than February 13, 2013, in order for the Landlord’s Work to be Substantially Complete by the Target Commencement Date (as defined in the Lease). Upon any dispute regarding the design of the Tenant Improvements, which is
not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final
decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable by Tenant to the
extent that they increase Landlord’s net cost to construct the Tenant Improvements, and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems. Any changes to the Tl
Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof. 

3. Performance of Landlord’s Work. 

(a) Definition of landlord’s Work. As used herein, “Landlord’s Work” shall mean the work of constructing the
Tenant Improvements. 
 (b) Commencement and Permitting. Landlord shall commence construction of the Tenant Improvements upon
obtaining a building permit (the “TI Permit”) authorizing the construction of the Tenant Improvements consistent with the Tl Construction Drawings approved by Tenant. The cost of obtaining the Tl Permit shall be payable by Landlord.
Tenant shall assist Landlord in obtaining the Tl Permit. If any Governmental Authority having jurisdiction over the construction of Landlord’s Work or any portion thereof shall impose terms or conditions upon the construction thereof that:
(i) are inconsistent with Landlord’s obligations hereunder, (ii) increase the cost of constructing Landlord’s Work, or (iii) will materially delay the construction of Landlord’s Work, Landlord and Tenant shall
reasonably and in good faith seek means by which to mitigate or eliminate any such adverse terms and conditions. 
 (c) Completion of
Landlord’s Work. Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in compliance with applicable laws, in accordance with the Tl Permit subject, in each case,
to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises (“Substantial Completion” or “Substantially Complete”). Upon Substantial
Completion of Landlord’s Work, Landlord shall require the Tl Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of
Architects (“AlA”) document G704. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or
to comply with any required permit (including the Tl Permit); (ii) to comply with any request by Tenant for modifications to Landlord’s Work; (iii) to comport with good design, engineering, and construction practices that are not
material; or (iv) to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlord’s Work. 

  
 



 










			
		  	343 Oyster/Calithera – Page 3

  

(d) Selection of Materials. Where more than one type of material or structure is indicated on the Tl Construction Drawings approved by
Landlord and Tenant, the option will be within Landlord’s reasonable discretion if the matter concerns the Tenant Improvements, and within Landlord’s sole and absolute subjective discretion if the matter concerns the structural components
of the Building or any Building system. As to all building materials and equipment that Landlord is obligated to supply under this Work Letter, Landlord shall select the manufacturer thereof in its sole and absolute subjective discretion, unless
otherwise specified in the construction drawings. 
 (e) Delivery of the Premises. When Landlord’s Work is Substantially
Complete, subject to the remaining terms and provisions of this Section 3(e) and Landlord’s obligation to complete the punch list items, Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the
Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any
non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the Tl Construction Drawings
(subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such
Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be
in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such
Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor, provided that Tenant shall defend with counsel reasonably acceptable to Landlord, indemnify and hold
Landlord harmless from and against any claims arising out of or in connection with any such claim. 
 (f) Tenant shall be entitled to
receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and
suppliers of such equipment, but the cost of any such extended warranties shall be borne solely by Tenant. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items in a good and workmanlike manner in compliance
with applicable Legal Requirements promptly after the Commencement Date. 
 (g) Commencement Date Delay. Except as otherwise provided
in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes
(“Tenant Delay”): 
 (i) Tenant’s Representative was not available during normal business hours to give
or receive any Communication or to take any other action required to be taken by Tenant hereunder; 
 (ii) Tenant’s
request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed; 

(iii) Construction of any Change Requests; 

(iv) Tenant’s request for materials, finishes or installations requiring unusually long lead times, provided that Landlord
informed Tenant in writing at the time of Tenant’s request that the requested items would require unusually long lead times; 

(v) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein; 

  
 



 










			
		  	343 Oyster/Calithera – Page 4

  

(vi) Tenant’s delay in providing information critical to the normal progression of the Project. Tenant shall provide such
information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord; 

(vii) Tenant’s delay in making payments to Landlord for Excess Tl Costs (as defined in Section 5(b) below); or

 (viii) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of
such persons. 
 If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the Tl Architect to certify the date on which the Tenant
Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be the date of Delivery. 
 4.
Changes. Any changes requested by Tenant to the Tenant Improvements after the delivery and approval by Landlord of the Space Plan shall be requested and instituted in accordance with the provisions of this Section 4 and shall be
subject to the written approval of Landlord and the Tl Architect, such approval not to be unreasonably withheld, conditioned or delayed. 

(a) Tenant’s Request For Changes. If Tenant shall request changes to the Tenant Improvements (“Changes”), Tenant
shall request such Changes by notifying Landlord in writing in substantially the same form as the AlA standard change order form (a “Change Request”), which Change Request shall detail the nature and extent of any such Change. Such
Change Request must be signed by Tenant’s Representative. Landlord shall, before proceeding with any Change, use commercially reasonable efforts to respond to Tenant as soon as is reasonably possible with an estimate of: (i) the time it
will take, and (ii) the architectural and engineering fees and costs that will be incurred, to analyze such Change Request (which costs shall be paid by Tenant to the extent actually incurred, whether or not such change is implemented).
Landlord shall thereafter submit to Tenant in writing, within 5 business days of receipt of the Change Request (or such longer period of time as is reasonably required depending on the extent of the Change Request), an analysis of the additional
cost or savings involved, including, without limitation, architectural and engineering costs and the period of time, if any, that the Change will extend the date on which Landlord’s Work will be Substantially Complete. Any such delay in the
completion of Landlord’s Work caused by a Change, including any suspension of Landlord’s Work while any such Change is being evaluated and/or designed, shall be Tenant Delay. 

(b) Implementation of Changes. If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for
completion of Landlord’s Work, if any, and (ii) deposits with Landlord any Excess Tl Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by
Tenant of any estimate of the delay caused by such proposed Change, the Tl Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant. 

5. Costs. 
 (a)
Tl Costs. Landlord shall be responsible for the payment of design, permits and construction costs in connection with the construction of the Tenant Improvements, including, without limitation, the cost of preparing the Tl Construction
Drawings and the Space Plans and Landlord’s out-of- pocket expenses (collectively, “TI Costs”). Notwithstanding anything to the contrary contained herein, in no event shall Landlord be
required to pay for any furniture, personal property or other non-Building system materials or equipment, including, but not limited to, Tenant’s voice or data cabling, non-ducted biological safety cabinets and other scientific equipment not
incorporated into the Tenant Improvements. 
 (b) Excess Tl Costs. Notwithstanding anything to the contrary contained herein, Tenant
acknowledges and agrees that Landlord shall have no responsibility for any costs arising from or related to Tenant’s changes to the Space Plan or Tl Construction Drawings, Tenant Delays and the cost of


  
 



 










			
		  	343 Oyster/Calithera – Page 5

  


Changes and Change Requests (collectively, “Excess Tl Costs”); provided, however, Tenant shall only be responsible for the same to the extent of any increase Landlord’s net
cost to construct the Tenant Improvements. If any Excess Tl Costs will result in an increase of Landlord’s net cost to construct the Tenant Improvements, Landlord shall deliver to Tenant a copy of the Landlord’s original budget for Tl
Costs. Upon Landlord’s request from time to time, Tenant shall deposit with Landlord, as a condition precedent to Landlord’s obligation to complete the Tenant Improvements, 100% of the Excess Tl Costs. If Tenant fails to deposit the Excess
Tl Costs with Landlord, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes
of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease. 
 6. Tenant
Access. 
 (a) Tenant’s Access Rights. Landlord hereby agrees to permit Tenant access, at Tenant’s sole risk and
expense, to the Building (i) 10 days prior to the Commencement Date to perform any work (“Tenant’s Work”) required by Tenant other than Landlord’s Work, provided that such Tenant’s Work is coordinated with the Tl
Architect and the general contractor, and complies with the Lease and all other reasonable restrictions and conditions Landlord may impose, and (ii) prior to the completion of Landlord’s Work, to inspect and observe work in process; all
such access shall be during normal business hours or at such other times as are reasonably designated by Landlord. Notwithstanding the foregoing, Tenant shall have no right to enter onto the Premises or the Project unless and until Tenant shall
deliver to Landlord evidence reasonably satisfactory to Landlord demonstrating that any insurance reasonably required by Landlord in connection with such pre-commencement access (including, but not limited to, any insurance that Landlord may require
pursuant to the Lease) is in full force and effect. Any entry by Tenant shall comply with all established safety practices of Landlord’s contractor and Landlord until completion of Landlord’s Work and acceptance thereof by Tenant. 

(b) No Interference. Neither Tenant nor any Tenant Party (as defined in the Lease) shall interfere with the performance of
Landlord’s Work, nor with any inspections or issuance of final approvals by applicable Governmental Authorities, and upon any such interference, Landlord shall have the right to exclude Tenant and any Tenant Party from the Premises and the
Project until Substantial Completion of Landlord’s Work. 
 (c) No Acceptance of Premises. The fact that Tenant may, with
Landlord’s consent, enter into the Project prior to the date Landlord’s Work is Substantially Complete for the purpose of performing Tenant’s Work shall not be deemed an acceptance by Tenant of possession of the Premises, but in such
event Tenant shall defend with counsel reasonably acceptable by Landlord, indemnify and hold Landlord harmless from and against any loss of or damage to Tenant’s property, completed work, fixtures, equipment, materials or merchandise, and from
liability for death of, or injury to, any person, caused by the act or omission of Tenant or any Tenant Party. 
 7.
Miscellaneous. 
 (a) Consents. Whenever consent or approval of either party is required under this Work Letter, that
party shall not unreasonably withhold, condition or delay such consent or approval, unless expressly set forth herein to the contrary. 

(b) Modification. No modification, waiver or amendment of this Work Letter or of any of its conditions or provisions shall be binding
upon Landlord or Tenant unless in writing signed by Landlord and Tenant. 

  
 



 










			
	Work Letter – Landlord Build	  	343 Oyster/Calithera – Page 6

  

SCHEDULE 1 
 Space
Plan 
  
  
 



 

  
 



 










			
	Work Letter – Landlord Build	  	343 Oyster/Calithera – Page 7

  

SCHEDULE 2 
 Scope of
Work 
  
  
 



 

  
 



 










			
	Work Letter – Landlord Build	  	343 Oyster/Calithera – Page 8

  
  





 

  
 



 










			
		  	343 Oyster/Calithera – Page 1

  

EXHIBIT D TO LEASE 

ACKNOWLEDGEMENT OF COMMENCEMENT DATE 

This ACKNOWLEDGMENT OF COMMENCEMENT DATE is made this      day of
            ,     , between ARE-TECHNOLOGY CENTER SSF, LLC, a Delaware limited liability company (“Landlord”), and CALITHERA BIOSCIENCES,
INC., a Delaware corporation (“Tenant”), and is attached to and made a part of the Lease dated February 14, 2013 (the “lease”), by and between Landlord and Tenant. Any initially capitalized terms used but not
defined herein shall have the meanings given them in the Lease. 
 Landlord and Tenant hereby acknowledge and agree, for all purposes of the
Lease, that the Commencement Date of the Base Term of the Lease is                     ,          and the
termination date of the Base Term of the Lease shall be midnight on                     ,         . In case
of a conflict between the terms of the Lease and the terms of this Acknowledgment of Commencement Date, this Acknowledgment of Commencement Date shall control for all purposes. 

IN WITNESS WHEREOF, Landlord and Tenant have executed this ACKNOWLEDGMENT OF COMMENCEMENT DATE to be effective on the date first above
written. 
  

							
	TENANT:
	
	 CALITHERA BIOSCIENCES, INC.,

a Delaware corporation

		
	By:	 	  

	Its:	 	  

	
	LANDLORD:
	
	 ARE-TECHNOLOGY CENTER SSF, LLC,

a Delaware limited liability company

		
	By:	 	ALEXANDRIA REAL ESTATE EQUITIES, L.P.,
		 	a Delaware limited partnership,
		 	managing member
			
		 	By:	 	ARE-QRS CORP.,
		 		 	a Maryland corporation,
		 		 	general partner,
				
		 		 	By:	 	  

		 		 	Its:	 	  

		 		 		 	  




  
 



 










			
	Rules and Regulations	  	343 Oyster/Calithera – Page 1

  

EXHIBIT E TO LEASE 

Rules and Regulations 

1. The sidewalk, entries, and driveways of the Project shall not be obstructed by Tenant, or any Tenant Party, or used by them for any purpose
other than ingress and egress to and from the Premises. 
 2. Tenant shall not place any objects, including antennas, outdoor furniture,
etc., in the parking areas, landscaped areas or other areas outside of its Premises, or on the roof of the Project. 
 3. Except for animals
assisting the disabled, no animals shall be allowed in the offices, halls, or corridors in the Project 
 4. Tenant shall not disturb the
occupants of the Project or adjoining buildings by the use of any radio or musical instrument or by the making of loud or improper noises. 

5. If Tenant desires telegraphic, telephonic or other electric connections in the Premises, landlord or its agent will direct the electrician
as to where and how the wires may be introduced; and, without such direction, no boring or cutting of wires will be permitted. Any such installation or connection shall be made at Tenant’s expense. 

6. Tenant shall not install or operate any steam or gas engine or boiler, or other mechanical apparatus in the Premises, except as
specifically approved in the Lease. The use of oil, gas or inflammable liquids for heating, lighting or any other purpose is expressly prohibited. Explosives or other articles deemed extra hazardous shall not be brought intothe Project. 

7. Parking any type of recreational vehicles is specifically prohibited on or about the Project. Except for the overnight parkihg of operative
vehicles, rio vehicle of any type shall be stored in the parking areas at any time. lh the event that a vehicle is disabled, it shall be removed within 48 hours. There shall be no “ForSale” or other advertising signs on or about any parked
vehicle. All vehicles shall be parked in the designated parking areas in conformity with all signs and other markings. All parking will be open parking, and no reserved parking, numbering or lettering of individual spaces will be permitted except as
specified by Landlord. 
 8. Tenant shall maintain the Premises free from rodents, insects and other pests. 

9. Landlord reserves the right to exclude or expel from the Project any person who, in the judgment of Landlord, is intoxicated or under the
influence of liquor or drugs or who shall in any manner do any act in violation of the Rules and Regulations of the Project. 
 10. Tenant
shall not cause any unnecessary labor by reason of Tenant’s carelessness or indifference in the preservation of good order and cleanliness. Landlord shall not be responsible to Tenant for any loss of property on the Premises, however occurring,
or for any damage done to the effects of Tenant by the janitors or any other employee or person. 
 11. Tenant shall give Landlord prompt
notice of any defects in the water, lawn sprinkler, sewage, gas pipes, electrical lights and fixtures, heating apparatus, or any other service equipment affecting the Premises. 

12. Tenant shall not permit storage outside the Premises, including without limitation, outside storage of trucks and other vehicles, or
dumping of waste or refuse or permit any harmful materials to be placed in any drainage system or sanitary system in or about the Premises. 

  
 



 










			
	Rules and Regulations	  	343 Oyster/Calithera – Page 2

  

13. All moveable trash receptacles provided by the trash disposal firm for the Premises must be kept in the trash enclosure areas, if any,
provided for that purpose. 
 14. No auction, public or private, will be permitted on the Premises or the Project. 

15. No awnings shall be placed over the windows in the Premises except with the prior written consent of Landlord. 

16. The Premises shall not be used for lodging, sleeping or cooking or for any immoral or illegal purposes or for any purpose other than that
specified in the Lease. No gaming devices shall be operated in the Premises. 
 17. Tenant shall ascertain from landlord the maximum amount
of electrical current which can safely be used in the Premises, taking into account the capacity of the electrical wiring in the Project and the Premises and the needs of other tenants, and shall not use more than such safe capacity. Landlord’s
consent to the installation of electric equipment shall not relieve Tenant from the obligation not to use more electricity than such safe capacity. 

18. Tenant assumes full responsibility for protecting the Premises from theft, robbery and pilferage. 

19. Tenant shall not install or operate on the Premises any machinery or mechanical devices of a nature not directly related to Tenant’s
ordinary use of the Premises and shall keep all such machinery free of vibration, noise and air waves which may be transmitted beyond the Premises. 

  
 



 










			
		  	343 Oyster/Calithera – Page 1

  

EXHIBIT F TO LEASE 

TENANT’S PERSONAL PROPERTY 

None.