EXHIBIT 10.1


 


 





		GEOPHYSICAL COMPANY	SEISMOGRAPH SURVEYS







 


508 WEST WALL, SUITE 800


MIDLAND, TEXAS 79701.5010


TELEPHONE 432.684.3000


FACSIMILE 432.684.3030


 


 


 


 


July 23, 2014


 


 


 


 


Gray Fox Petroleum Corporation


3333 Lee Parkway,
Suite 600


Dallas, Texas 75219


 


Attention: Lawrence Pemble


 


Dear Mr. Pemble:


 


Enclosed please find two (2)
copies of our Master Geophysical Data Acquisition Agreement for your review.


 


If this meets with your approval,
please sign and initial where noted and return one copy of the document for our files.


 


If you have any questions, please let me know.


 


Very truly yours,


 


DAWSON GEOPHYSICAL COMPANY


 


By: /s/ David Wisniewski


        David Wisniewski


        Vice President


 


 


DW/BS/ng


 


Enclosure


 






    	 



    	 



    

 


MASTER GEOPHYSICAL


DATA ACQUISITION AGREEMENT


Between


GRAY FOX PETROLEUM CORPORATION

("Company")


And


DAWSON GEOPHYSICAL COMPANY

("Contractor")


Dated: July 23, 2014


 






    	 



    	 



    

 


TABLE OF CONTENTS


	CLAUSE	PAGE No.
	 	 	 
	1.	NATURE OF WORK	1
	2.	SUPPLEMENTAL AGREEMENTS	 
	3.	PERSONNEL, EQUIPMENT AND SUPPLIES	2
	4.	CONDUCT OF OPERATIONS	2
	5.	PERMITS	4
	6.	REPORTS	4
	7.	CONFIDENTIALITY	5
	8.	INDEMNITY	6
	9.	INSURANCE	9
	10.	COMPLIANCE WITH LAWS/HES	10
	11.	COMPANY REPRESENTATIVE	10
	12.	TAXES	10
	13.	COMPENSATION/CONTRACTOR'S RIGHTS	11
	14.	INTELLECTUAL PROPERTY	11
	15.	INDEPENDENT CONTRACTOR	12
	16.	ASSIGNMENT AND SUBCONTRACTS	12
	17.	FORCE MAJEURE	12
	18.	AUDIT	13
	19.	TERM AND RENEWAL	13
	20.	NOTICES	13
	21.	APPLICABLE LAWS/DISPUTES	13
	22.	WAIVER	14
	23.	DEFAULT	14
	24.	SURVIVAL OF TERMS	15
	25.	INUREMENT	15
	26.	ENTIRE AGREEMENT/MODIFICATION	15
	27.	COUNTERPARTS	15


 






    	 



    	 



    

 


MASTER
GEOPHYSICAL


DATA
ACQUISITION AGREEMENT


 


This MASTER
GEOPHYSICAL DATA ACQUISITION AGREEMENT (the "Master Agreement" or "Agreement") is entered into
this 23rd day of July, 2014; between Gray Fox Petroleum Corporation, having an office located in Dallas, Texas (hereinafter called
"Company") as well as, any legal entity which controls, is controlled by or is under common control of the Company
(the "Affiliate" or "Affiliates")and Dawson Geophysical Company, a Texas corporation having
offices in Midland, Texas (hereinafter called "Contractor") and its Affiliates. Company and Contractor may each
be referred to herein as "Party" or collectively as "Parties".


 


For and
in consideration of the mutual covenants and promises of the Parties herein set forth, the Parties do hereby agree as follows:


 


1.      NATURE
OF WORK


 


1.1     Contractor
shall conduct, for the benefit of Company, field geophysical data acquisition surveys (the "Surveys" or the "Work")
and related services in search of subsurface geological formations and structures favorable to the accumulation of oil, gas and
mineral deposits underlying those land areas designated, from time to time, by Company and accepted by Contractor, all in accordance
with the terms and conditions of this Agreement, and the applicable Supplemental Agreement. Contractor, if requested by Company,
shall also provide data processing of and for the field data ("Data") so acquired.


 


1.2     Such
Survey(s) shall be conducted by one or more geophysical crews, as may be agreed upon by Contractor and Company, in such a manner
and subject to the terms and conditions as set forth herein and in the applicable Supplemental Agreement. If data processing services
are requested, such services shall be done in Contractor's data processing service centers in Midland, Texas; Houston, Texas;
or Oklahoma City, Oklahoma.


 


1.3     Nothing
herein shall require Company to contract with Contractor or Contractor to accept assignments from Company to conduct Survey(s),
except as may be agreed upon, from time to time, in an appropriate Supplemental Agreement.


 


2.      SUPPLEMENTAL
AGREEMENTS


 


2.1     (General) Whenever
Company requests, and Contractor agrees, to conduct a Survey on behalf of Company, Contractor and Company shall enter into separate
Supplemental Agreements for each separate Survey so undertaken, which Supplemental Agreements shall be consecutively numbered
for identification and shall provide the following:


		(a)	The area(s) (state, county/parish,
                                         etc,) where the Survey(s) will be conducted ("Area of Operations").
		(b)	The approximate commencement date,
                                         if applicable, of the Survey(s) ("Commencement Date").
	 	(c)	The approximate period of time or number of
miles (or square miles), if applicable, that will be required to complete the Survey(s).
		(d)	The type of Survey(s) to be conducted.
                                         The equipment, instruments, personnel and other items ("Crew") which
                                         will be required for the Survey(s).
		(e)	The parameters and other technical aspects of the Survey(s) and/or the processing of the Data acquired
thereby.
	 	(f)	The compensation to be paid Contractor for conducting the Survey(s)
                           ("Compensation").
	 	(g)	Any other matters of a business, operational
or technical nature as may be agreed by the Parties.



 


2.2     (Crew
Availability) It is recognized that difficulties in scheduling the activities of Contractor's geophysical crews may result
in overlap or conflicts which prevent Contractor from providing geophysical Crews to conduct a particular Survey designated by
Company at the time desired. Contractor shall make every reasonable effort to avoid such overlaps or conflicts in furnishing Company
a geophysical Crew for any designated Survey. In the event of any such conflict, however, Contractor shall notify Company promptly
after such Survey has been requested by Company that Contractor will be unable to conduct the Survey pursuant to Company's time
schedule. There shall then be, if feasible, at the election of Company, an agreed alternate date between Company and Contractor
that shall be a firm date for commencement of the Survey by Contractor. If no such alternate date can be agreed upon, then Contractor
shall thereafter have no obligations hereunder in connection with not conducting said Survey.


 


Page 1 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


2.3     (Incorporation
by Reference) Each Supplemental Agreement shall be incorporated herein by reference, and all terms and provisions of this
Agreement shall apply to each Supplemental Agreement unless, in any particular Supplemental Agreement, any of the terms and conditions
hereof are eliminated or modified for purposes of that Supplemental Agreement by specific reference to those terms and conditions
hereof to be eliminated or modified. Any Supplemental Agreement incorporated herein and subject, thereby, to the terms and conditions
hereof shall hereinafter be referred to as "Supplemental Agreement" or "Supplement." This Master
Agreement and any applicable Supplemental Agreements may collectively be referred to as "this Agreement."


 


2.4     (Conflicting
Terms) In the event of a conflict between any of the terms and conditions of this Master Agreement and those of any
Supplemental Agreement, the appropriate terms of this Agreement shall govern and control, unless specifically provided to the
contrary in any Supplemental Agreement, as provided above, or where a provision herein states that it is subject to or
otherwise anticipates contrary terms of a Supplement. The fact that additional terms or provisions appear in one or the other
document shall not, in and of itself, create a conflict.


 


3.      PERSONNEL,
EQUIPMENT AND SUPPLIES


 


3.1     (General) The Contractor shall
furnish, place in service and maintain, at its sole cost and expense, for the performance of Survey(s) hereunder, the Crew
more particularly described in Supplemental Agreements annexed hereto.


 


3.2     (Additional/Different
Personnel or Equipment) Changing operating conditions may require the Crew personnel and equipment set forth in said
Supplemental Agreements to be increased, reduced or changed or the Area of Operations or the parameters of the Survey
changed. Accordingly, Contractor shall, when authorized by Company, furnish such auxiliary or additional personnel,
equipment, supplies and services or make such other changes as may be required in connection therewith all as more
particularly set forth and described in the Supplemental Agreements or amendments thereto, which shall clearly set forth the
additional compensation, if any, to be paid to the Contractor as a result of such changes.


 


4.      CONDUCT
OF OPERATIONS


 


4.1     (Conduct of Operations by Contractor)
In conducting operations hereunder, Contractor shall use its best efforts to conduct all operations hereunder in accordance
with the terms and specifications of this Agreement (and those of the applicable Supplemental Agreement) and in conformance
with generally accepted practices of the geophysical data acquisition industry. In particular, Contractor agrees that, in
conducting operations under the terms hereof it will:


		(a)	Enter upon no lands in respect of which all necessary Land Entry Permits shall not have been
                                                                 first obtained, as provided in Clause 5 below.
		(b)	Equip its Crew with instruments and equipment as specified in the Supplemental Agreement and
                                                                 maintain such equipment in good operating condition and provide its Crew with qualified and experienced personnel.
	 	(c)	Perform all Survey(s) hereunder
in an orderly, efficient and workmanlike manner in compliance with the terms of this Agreement and each Supplemental Agreement
and all applicable laws, ordinances, rules and regulations for the time being in force in every state and locality wherein the
Survey(s) hereunder is to be performed.
		(d)	Comply fully with the provisions of all worker's compensation legislation, ordinances, rules
                                                                 and regulations in force in every state wherein the Survey(s) is (are) to be performed.
		(e)	Initiate all energy source units at a safe distance from water wells, buildings and other
                                                                 structures owned by third parties for the purpose of avoiding, as far as reasonably possible and consistent with prudent
                                                                 geophysical operations, damage to such wells, buildings and other structures.
	 	(f)	Attempt
to minimize disturbance to the surface of the land and all crops and other vegetation thereon. Liability for any subsequent
requirements for erosional or pollution repair or prevention which has not been caused by
the negligence or other fault of Contractor shall rest solely with Company under Clause 8.4 below, which liability shall survive
the termination of this Agreement.



 


Page 2
of 15


MASTER
GEOPHYSICAL DATA ACQUISITION AGREEMENT






    	 



    	 



    




 


4.2     (Company's Obligations) Company agrees
with Contractor that it will:


		(a)	Not require Contractor to do any matter, act or thing in the
                                                                performance of the Survey(s) hereunder that is contrary to or in violation of any law, ordinance, rule or regulation
                                                                governing the subject matter of this Agreement.
		(b)	in the event Company is responsible, under the terms of any
                                                                Supplemental Agreement, for obtaining Land Entry Permits (Clause 5 below) and/or the surveying, shot-hole drilling or other
                                                                components of a Survey (whether such services will be provided by Company or other contractors of Company), cause such
                                                                services to be provided in a timely and competent manner and shall be responsible, to the extent provided herein and in the
                                                                Supplemental Agreement, and indemnify, save and hold Contractor harmless for all costs, losses and liabilities related
                                                                thereto.
		(c)	Designate, sufficiently in advance to permit orderly planning of the
                                                                Survey by Contractor, each area to be surveyed and shall furnish Contractor with all land and base maps, subsurface well data
                                                                and all other information that may be necessary or helpful to the conduct of the Survey(s), all of which shall be considered
                                                                the property of Company to be held by Contractor confidential as provided in Clause 7 below.



 


4.3     (Work Time) Normal hours and days
of work, time off and holidays to be observed shall be as provided in the applicable Supplemental Agreements hereto or as
otherwise agreed by the Parties.


 


4.4     (Progress of the Work) Contractor
shall keep Company fully informed on a timely basis of the progress of operations and results obtained during the course of
the Work hereunder and shall consult with Company's Representative(s) concerning planning of the Work and the seismic data
collected. Progress reports shall be furnished by Contractor as provided in Clause 6 below.


 


4.5     (No Liens)


 


4.5.1     Contractor shall not allow any
mechanic's or materialmen's liens or encumbrances to become attached to any property of Company resulting from the Work
performed by Contractor hereunder; provided, however, that Contractor itself may file mechanic's, materialman's or other
liens as may be appropriate to secure payment by the Company to Contractor under this Agreement. Likewise, Contractor shall
be solely responsible for, and shall promptly pay, when due, all obligations for labor and material supplied by third parties
for Work to be performed hereunder and shall indemnify and save Company harmless from and against any and all claims, liens,
security interests or other encumbrances on or against Company property on account of labor performed or materials furnished
to Contractor by its subcontractors, suppliers and vendors for such Work; provided, however, that Contractor shall not be
required to make payment of any such claim where a bona fide dispute with regard thereto exists between Contractor and its
vendors or suppliers. Contractor shall provide Company with recordable Releases for all such claims and liens so
satisfied.


 


4.5.2      Company may, if it so elects, pay
or discharge any such lien or encumbrance and may thereupon deduct the amount or amount so paid by Company from any sums been
due or which thereafter shall become due to Contractor under the terms hereof; provided, however, that prior to discharging
any such lien or encumbrance, Company will consult with Contractor in order to determine whether or not there is a bona fide
dispute between Contractor and its supplier or subcontractor concerning the claim underlying the lien or encumbrance. If such
a bona fide dispute does exist, Company shall delay discharging the affected lien or encumbrance until the matter is
resolved.


 


4.6     (Title
to Data) Except as provided elsewhere in this Agreement or in any Supplemental Agreement, title to all Data shall pass to
Company when acquired by Contractor and subject to payment by the Company to Contractor of all of Contractor's obligations hereunder,
and Contractor shall deliver all Data to Company retaining no copies thereof; provided, however, that Contractor shall deliver
to Company all records, maps, reports or other information which has been produced by the work performed hereunder upon termination
of this Agreement, if so required in writing by the Company.


 


Page 3 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


4.7     (Waiver of Mineral Interest) Unless otherwise specifically
provided for in this Agreement or any Supplemental Agreement hereto, Contractor, for itself and its subcontractors and the officers,
directors and employees thereof, hereby waives any right, title or interest it may have in, and to any discovery of; hydrocarbon
or other mineral deposits which may be made by reason for the Work performed under the terms of this Agreement.


 


5.      PERMITS


 


5.1     (General)
Unless Company assumes the permitting responsibility under Clause 5.3 below, Contractor shall, at Company's request and expense,
obtain such permits, licenses and clearances (the "Land Entry Permits"). Company's cost shall include entry fees
and damage payments as well as payments to governmental agents, per diem, if any, needed to secure such Land Entry Permits. Contractor
will use its reasonable efforts to secure written Land Entry Permits from the person or persons representing themselves to be
owners or lessees of the areas involved. Contractor will not enter upon lands where Land Entry Permits have not been obtained
by it (or represented by Company as having been obtained by it) unless otherwise directed, in writing with full indemnification
in favor of Contractor, at Company's sole risk, by Company to do so.


 


5.2     (Permit
Fees) In the event it becomes necessary to pay for permission to enter upon any area connected with the Survey,
Contractor will notify Company of such area involved and the fees required in order to obtain the Land Entry Permits and will
proceed with the consent of Company's Representative. Company will reimburse Contractor the cost of all such Permits unless
otherwise provided in the applicable Supplemental Agreement.


 


5.3     (Permits
Obtained by Company) In the event Company assumes the responsibility for obtaining or supervising the obtaining of all or
some Land Entry Permits from land owners, mineral owners, appropriate governmental agencies, lessees, tenants, and all other
persons having permissible interests in the land or its subsurface minerals, in the Area of Operations, as may be required in
connection with all such Survey(s) to be performed by Contractor under this Agreement, either by utilizing Company personnel
or those of third party contractors (whether individuals, corporate or otherwise), Company shall have the obligations set
forth in Clause 8.6 below and Contractor shall not be responsible for any delays in its operations caused by (i) the
inability of Company to acquire any Permit on a timely basis or (ii) onerous provisions contained in such Permits which
impede or adversely affect the operations of Contractor hereunder. Contractor shall be compensated during any such delays at
the standby rate set forth in the applicable Supplement. If Company acquires Land Entry Permits, it will provide copies
thereof to Contractor sufficiently in advance of operations in order for Contractor to properly plan its operations.


 


6.      REPORTS


 


6.1     (Required Reports) During the
course of the Survey(s), Contractor shall furnish Company with such periodic production and progress reports as provided in
the applicable Supplemental Agreement or, if not so provided, as Company shall reasonably require, including (subject to
Clause 7.2 below) such reports as may be required by the various agencies of the federal, state and local authorities where
the Survey is being performed.


 


6.2     (Completion
Report) As soon as possible upon completion of each Survey, Contractor shall furnish Company with reports and data as
follows:


 


		(a)	A final report consisting of a written description of the Survey(s) performed
and the results thereof accompanied by maps on a base supplied by Company of all data considered necessary by Company.
		(b)	All field data sheets, computation sheets, seismograph records, weathering
data, and engineering data as may have been generated in the performance of the Survey(s), which reports and materials shall be
permanent property of Company but accessible to Contractor for technical examination any time prior to the expiration of this Agreement.
		(c)	Any other reports or data as may be provided for in the applicable Supplemental Agreement.



 


Contractor shall not be required
to include in reports prepared for, or information or data supplied to Company hereunder, any data or information proprietary to
Contractor, including, but not limited to, that pertaining to its instruments, equipment, methods or expertise.


 


Page 4 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


6.3     (USE
OF REPORTS) THE RESULTS STATED AND THE CONCLUSIONS DRAWN FROM ALL REPORTS FURNISHED BY CONTRACTOR TO COMPANY HEREUNDER SHALL
REPRESENT THE BEST OPINION, EFFORTS AND JUDGMENT OF THE CONTRACTOR; HOWEVER, CONTRACTOR CANNOT AND
MASTER GEOPHYSICAL DATA ACQUISITION AGREEMENT DOES NOT WARRANT OR GUARANTEE THE ACCURACY OR CORRECTNESS THEREOF. ANY ACTION WHICH
COMPANY (OR THOSE ASSOCIATED WITH COMPANY) MAY TAKE AS A RESULT OF OR BASED ON SUCH REPORTS AND THE DATA TO WHICH IT REFERS SHALL
BE ITS OWN RESPONSIBILITY AND CONTRACTOR SHALL NOT BE LIABLE OR RESPONSIBLE FOR ANY LOSS, COST, DAMAGES OR EXPENSES WHATSOEVER,
INCLUDING INCIDENTAL OR CONSEQUENTIAL DAMAGES, INCURRED OR SUSTAINED BY COMPANY RESULTING THEREFROM FOR WHICH COMPANY HEREBY RELEASES
CONTRACTOR; PROVIDED THAT ALL SUCH REPORTS, DATA AND INFORMATION, AS WELL AS THE BASIC DATA UPON WHICH THEY ARE BASED, ARE ACQUIRED,
COMPILED AND PREPARED, AS THE CASE MAY BE, IN ACCORDANCE WITH THE TERMS OF THIS AGREEMENT.


 


6.4     (Access
to Data) Company shall at all times have complete access to all geophysical records and such other data of Contractor relating
to the Work and all such data and records shall, at the conclusion of the Work, belong exclusively to Company, but shall be retained
by the Contractor pending instructions to be issued by Company with regard to the deposition thereof, subject to the terms and
conditions of clauses 5 above and 13.6 below.


 


7.      CONFIDENTIALITY


 


7.1     (Confidentiality
of Data) Contractor shall use its best efforts to safeguard (i) geophysical Data acquired from the Work performed hereunder,
(ii) information relating to the location of the Surveys and the type of Work performed and (iii) information supplied by Company
to Contractor which is not otherwise proprietary to Contractor. Contractor shall not divulge to anyone, other than Company, its
designated agents or employees, any such Data or information unless previously authorized by Company in writing. Contractor shall
further use its best efforts to cause its employees, agents and subcontractors to comply with this obligation of secrecy. Reciprocally,
Company shall observe the above secrecy obligation, insofar as it has access to and knowledge of the equipment, instruments, programs,
procedures, and the design and operation thereof, which are proprietary to Contractor.


 


7.2     (Confidentiality
Exceptions) The obligations of confidentiality and limited use contained in this Agreement shall not apply to information
subject to this Agreement which:


 


7.2.1     At
the time of disclosure to the receiving Party, was in the public domain as evidenced by written publications;


 


7.2.2     After
disclosure to the receiving Party, became part of the public domain by written publication through no fault of the receiving Party;


 


7.2.3     At
the time of disclosure to the receiving Party, was already in the possession of the receiving Party as evidenced by written records,
and was not acquired directly or indirectly from the disclosing Party;


 


7.2.4     After
disclosure to the receiving Party, the receiving Party acquired the information from a third party having the right to convey
the same, provided the receiving Party is not obligated to hold such information in confidence by such third party;


 


7.2.5     Is
furnished to a third party by the disclosing Party without any restriction on the third party's rights to disclose such information;
or


 


7.2.6     Is
authorized in writing by the disclosing Party to be released from the confidentiality and limited use obligations herein.


 


7.2.7     Is
covered by Clause 7.3 below.


 


7.3     (Government
Reporting) It is understood that it is the responsibility of Company and Contractor to comply with applicable laws, regulations,
rules, court or government agency order or stock exchange regulation or rule regarding the making of reports and disclosures to
appropriate governmental agencies of Data and information relating to the Work and Contractor shall promptly refer to Company
for appropriate action, including the seeking, at its sole cost, such protective action as it deems appropriate, any inquiry or
request received by it from any governmental agency respecting Data and information obtained under the terms thereof, and if Company
shall instruct Contractor not to comply with any such inquiry or request, Company shall defend and indemnify Contractor against
any loss, damage, fine or penalty or other sanction received, incurred or suffered by Contractor in consequence of complying with
such instruction.


 


Page
5 of 15


 MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


8.     INDEMNITY


 


8.1     (GENERAL) IN ORDER TO
ALLOCATE THE RESPECTIVE RESPONSIBILITIES OF COMPANY AND CONTRACTOR FOR LIABILITIES ARISING OUT OF PERSONAL INJURY OR PROPERTY
DAMAGE RELATED TO THE WORK, IT IS AGREED AS BETWEEN COMPANY AND CONTRACTOR THAT CERTAIN RESPONSIBILITIES AND LIABILITIES FOR
PERSONAL INJURIES AND PROPERTY DAMAGE ARISING OUT OF THE PERFORMANCE OF THIS AGREEMENT SHOULD BE ALLOCATED BETWEEN THEM IN
ORDER TO AVOID PROTRACTED LITIGATION BETWEEN COMPANY AND CONTRACTOR, ALONG WITH THE ASSOCIATED LEGAL EXPENSES AND SO THAT
INSURANCE OR SELF-INSURANCE MAY BE ARRANGED BY EACH PARTY AS NECESSARY TO PROTECT THEM AGAINST THESE EXPOSURES TO LOSS. THE
FOLLOWING SETS OUT THE SPECIFICS OF THE AGREEMENTS BETWEEN COMPANY AND CONTRACTOR AS TO THE ALLOCATION OF SUCH
RESPONSIBILITIES AND LIABILITIES.


 


INITIAL
DW L’P


 


8.2     (CONTRACTOR'S
RESPONSIBILITY) CONTRACTOR WILL PROTECT, DEFEND, INDEMNIFY AND HOLD COMPANY, ITS OFFICERS AND DIRECTORS, HARMLESS FROM AND
AGAINST ANY AND ALL CLAIMS, LOSS, EXPENSE, OR DAMAGES (INCLUDING COSTS OF DEFENSE ASSOCIATED THEREWITH) ARISING FROM ANY CAUSE
WHATSOEVER, OUT OF THE WORK TO BE PERFORMED UNDER THIS AGREEMENT, PROVIDED THAT THE CLAIM ARISES FROM CONTRACTOR'S OR ITS SUB-CONTRACTORS
NEGLIGENCE AND CONTRACTOR SHALL DEFEND COMPANY AT CONTRACTOR'S SOLE EXPENSE IN ANY LITIGATION INVOLVING THE SAME.


 


INITIAL
DW L’P


 


8.3     (COMPANY'S
RESPONSIBILITY) COMPANY WILL PROTECT, DEFEND, INDEMNIFY AND HOLD CONTRACTOR, ITS OFFICERS AND DIRECTORS, HARMLESS FROM
AND AGAINST ANY AND ALL CLAIMS, LOSS, EXPENSE, OR DAMAGES (INCLUDING COSTS OF DEFENSE ASSOCIATED THEREWITH) ARISING FROM ANY
CAUSE WHATSOEVER, OUT OF THE WORK TO BE PERFORMED UNDER THIS AGREEMENT, PROVIDED THAT CONTRACTOR HAS FULLY DISCHARGED
CONTRACTOR'S OBLIGATIONS UNDER THIS AGREEMENT AND COMPANY SHALL DEFEND CONTRACTOR AT COMPANY'S SOLE EXPENSE IN ANY LITIGATION
INVOLVING THE SAME, EXCEPTING ONLY CLAIMS MADE BY EMPLOYEES OF CONTRACTOR, FOR WHICH CONTRACTOR SHALL INDEMNIFY AND HOLD
COMPANY HARMLESS IN THE MANNER PROVIDED ABOVE.


 


INITIAL
DW L’P


 


8.4     (ROUTINE
LAND DAMAGE) NOTWITHSTANDING THE FOREGOING TO THE CONTRARY, COMPANY SHALL BE SOLELY RESPONSIBLE FOR AND SHALL PROTECT,
INDEMNIFY, DEFEND AND SAVE CONTRACTOR AND ITS SUBCONTRACTORS HARMLESS FROM AND AGAINST ANY AND ALL CLAIMS, LIABILITIES,
DEMANDS, CAUSES OF ACTION, JUDGMENTS AND SETTLEMENTS (INCLUDING ASSOCIATED COSTS AND REASONABLE ATTORNEYS' FEES) ARISING OUT
OF CLAIMED DAMAGES TO THE LAND ON WHICH CONTRACTOR HAS PERFORMED WORK, AS WELL AS THE CROPS, TREES, GRASS AND OTHER FLORA AND
FAUNA THEREON, WATER AND IRRIGATION WELLS, HOUSES AND OTHER STRUCTURES THEREON (COLLECTIVELY THE "LAND DAMAGES")
WHERE SUCH CLAIMED LAND DAMAGES RESULT FROM THE NON-NEGLIGENT OPERATIONS OF CONTRACTOR OR ITS SUBCONTRACTORS IN THE
PERFORMANCE OF THE WORK SUBJECT TO THIS AGREEMENT AND THE APPLICABLE SUPPLEMENT. THE FOREGOING OBLIGATIONS OF DEFENSE AND
INDEMNITY OF COMPANY SHALL NOT, HOWEVER, BE APPLICABLE IN THE EVENT AND TO THE EXTENT ANY SUCH CLAIMED LAND DAMAGES RESULT
FROM GROSS NEGLIGENCE ON BEHALF OF CONTRACTOR OR ITS SUBCONTRACTORS OR WHICH ARE OTHERWISE NOT IN ACCORDANCE WITH THE TERMS
OF THIS AGREEMENT OR THE APPLICABLE SUPPLEMENT.


 


INITIAL
DW L’P


 


Page 6 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


 


8.5     (LIABILITY INSURANCE)
THE INDEMNITY OBLIGATION OF THE RESPECTIVE PARTIES, AS SET FORTH IN CLAUSES 8.2, 8.3 AND 8.4 ABOVE, SHALL BE SUPPORTED
BY LIABILITY INSURANCE PROVIDED BY EACH PARTY IN THE AMOUNT OF THE LESSER OF (I) $1,000,000 OR (II) THE MINIMUM AMOUNT
REQUIRED BY APPLICABLE LAW.


 


INITIAL
DW L’P


 


8.6     (LAND ENTRY
PERMIT LIABILITY) COMPANY SHALL PROTECT, DEFEND, INDEMNIFY AND SAVE CONTRACTOR HARMLESS FROM AND AGAINST ANY CLAIM BY THE
OWNER OR LESSEE OF LAND AND/OR OF A MINERAL INTEREST IN LAND ON WHICH WORK IS PERFORMED HEREUNDER, WHICH CLAIM IS BASED UPON
ANY THEORY THAT (I) THE OPERATIONS OF CONTRACTOR HEREUNDER HAVE DEPRECIATED THE VALUE OF THE MINERALS UNDERLYING SUCH LAND,
(II) MINERAL TRESPASS, (III) THE WRONGFUL TAKING, CONVERSION OR DEPRIVATION OF SUBSURFACE AND/OR MINERAL INFORMATION OR (IV)
ANY SIMILAR THEORY OF RECOVERY (COLLECTIVELY "TRESPASS CLAIMS"). HOWEVER, THE FOREGOING INDEMNIFICATION OF COMPANY
SHALL NOT APPLY AND COMPANY SHALL NOT BE RESPONSIBLE FOR ANY TRESPASS CLAIMS IN ANY CASE AND TO THE EXTENT WHERE CONTRACTOR
NEGLIGENTLY FAILS TO OBSERVE CONDITIONS OR RESTRICTIONS CONTAINED IN ANY SUCH PERMITS, PROVIDED THAT SAME HAVE BEEN PROVIDED
BY COMPANY TO CONTRACTOR SUFFICIENTLY IN ADVANCE OF OPERATIONS ACROSS THE LANDS COVERED THEREBY.


 


INITIAL
DW L’P


 


8.7     (TAPE
RESPONSIBILITY) CONTRACTOR SHALL BE RESPONSIBLE FOR THE SAFEKEEPING OF FIELD TAPES WHILE SUCH TAPES ARE IN THE CUSTODY OF
CONTRACTOR UNTIL SUCH TIME AS CONTRACTOR DELIVERS SAID TAPES TO A REPRESENTATIVE OF COMPANY OR PLACES THEM IN THE POSSESSION
OF A CARRIER DESIGNATED BY COMPANY (OR IF COMPANY DOES NOT SO DESIGNATE A CARRIER, ANY REPUTABLE CARRIER SELECTED BY
CONTRACTOR) FOR DELIVERY TO COMPANY OR A THIRD PARTY DESIGNATED BY COMPANY. IN THE EVENT OF LOSS OF OR DAMAGE TO ANY TAPES
FOR WHICH CONTRACTOR IS RESPONSIBLE, AS PROVIDED HEREIN, CONTRACTOR'S SOLE AND ONLY RESPONSIBILITY TO COMPANY SHALL BE, AT
THE OPTION OF COMPANY, EITHER (I) REACQUIRE THE DATA AFFECTED BY SUCH LOSS OR DAMAGE OR TO (H) REFUND (OR GRANT CREDIT) TO
COMPANY FOR ALL COMPENSATION PAID (OR PAYABLE) TO CONTRACTOR WITH RESPECT TO SUCH DATA SO AFFECTED. NOTWITHSTANDING THE
FOREGOING, CONTRACTOR'S OBLIGATIONS HEREIN SHALL BE FULLY SATISFIED IN THE EVENT CONTRACTOR OR COMPANY HAS DUPLICATE,
UNDAMAGED COPIES OF THE AFFECTED DATA AND, IF CONTRACTOR HAS SUCH DUPLICATE TAPE, IT PROMPTLY PROVIDES SAME TO COMPANY
SUBJECT TO CLAUSE 4 ABOVE.


 


INITIAL
DW L’P


 


8.8     (WAGES/BENEFITS)
CONTRACTOR SHALL BE SOLELY LIABLE FOR THE PAYMENT OF (I) ALL WAGES AND SALARIES EARNED BY AND PAYABLE TO ITS EMPLOYEES
AS WELL AS FOR WITHHOLDING AND/OR PAYMENT OF ALL SOCIAL SECURITY TAXES, RETIREMENT PENSIONS, BENEFITS AND ANNUITIES, NOW, OR
HEREAFTER IMPOSED BY THE GOVERNMENT OF THE U.S.A. OR BY ANY STATE OR OTHER POLITICAL SUBDIVISION THEREOF AND (II) FOR
BENEFITS WHICH ARE NOW OR HEREAFTER OFFERED BY CONTRACTOR TO ITS EMPLOYEES. CONTRACTOR SHALL INDEMNIFY AND SAVE COMPANY, ITS
OFFICERS AND DIRECTORS, HARMLESS FROM ANY CLAIMS, DEMANDS OR LIABILITY FOR SUCH WAGES, SALARIES OR BENEFITS, AS WELL AS FOR
ANY WITHHOLDING OR SOCIAL SECURITY TAXES, CONTRIBUTIONS OR OTHER BENEFITS RELATED THERETO.


 


INITIAL
DW L’P


 


Page 7 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


8.9     (HANDLING OF CLAIMS)


 


8.9.1     (GENERAL) IN
THE EVENT EITHER PARTY HERETO LEARNS OF ANY CLAIM, LIABILITY, DEMAND OR CAUSE OF ACTION RELATING TO THIS AGREEMENT OR THE
PERFORMANCE OF IT, SAID PARTY SHALL GIVE NOTICE THEREOF AS PROMPTLY AS POSSIBLE TO THE OTHER PARTY. IF INDEMNIFICATION
IS REQUIRED BY ANY OF THE TERMS OF THIS AGREEMENT, THE RESPONSIBLE PARTY SHALL DEFEND THE OTHER AND PAY ALL SETTLEMENTS,
JUDGMENTS, COSTS, INCLUDING REASONABLE ATTORNEYS FEES, AND OTHER EXPENSES, WHETHER RELATED OR UNRELATED, SIMILAR OR
DISSIMILAR TO THE FOREGOING, INCIDENT THERETO. EACH PARTY, IF REQUESTED, AGREES TO COOPERATE WITH THE OTHER IN ANY SUCH
DEFENSE, AND THE RESPONSIBLE PARTY SHALL REIMBURSE THE OTHER FOR ALL REASONABLE EXPENSES INCURRED IN CONNECTION THEREWITH.


 


INITIAL
DW L’P


 


8.9.2     (CONTROL
OF DEFENSE) THE PARTY HERETO PROVIDING INDEMNITY TO THE OTHER PARTY SHALL HAVE THE RIGHT TO CONTROL THE DEFENSE OF
ANY SUCH CLAIM OR LAWSUIT WITH ATTORNEYS SELECTED BY SUCH PARTY OR ITS INSURERS. HOWEVER, THE OTHER PARTY SHALL HAVE THE
RIGHT, AT ITS SOLE EXPENSE, TO PARTICIPATE IN THE DEFENSE OF SUCH CLAIM OR LAWSUIT WITH LEGAL COUNSEL OF ITS OWN SELECTION.


 


INITIAL
DW L’P


 


8.10     (COMPANY’S
CO-VENTURES) IN THE EVENT COMPANY IS IN ASSOCIATION WITH, IS OPERATOR FOR OR HAS SOME OTHER CONTRACTUAL RELATIONSHIP WITH
OTHER COMPANIES, INDIVIDUALS OR OTHERS IN CONNECTION WITH THE WORK TO BE PERFORMED HEREUNDER, THE ABOVE INDEMNIFICATIONS EXTENDED
BY CONTRACTOR TO COMPANY SHALL ALSO EXTEND TO THOSE PARTIES, AND THEIR OFFICERS, DIRECTORS AND EMPLOYEES, TO WHICH COMPANY IS
CONTRACTUALLY RELATED.


 


INITIAL
DW L’P


 


8.11     (CONSEQUENTIAL
DAMAGES) NEITHER PARTY HERETO SHALL, NOTWITHSTANDING THE FOREGOING, BE LIABLE TO THE OTHER PARTY FOR ANY SPECIAL, INCIDENTAL,
CONSEQUENTIAL OR PUNITIVE DAMAGES ARISING, IN ANY EVENT, FROM THE CONDUCT OF THE PARTIES UNDER THE TERMS HEREOF, INCLUDING WITHOUT
LIMITATION, LOSS OF REVENUE OR PROFITS. FURTHERMORE EACH PARTY HEREBY FOREVER RELEASES AND INDEMNIFIES THE OTHER FROM AND AGAINST
ANY AND ALL CLAIMS, LIABILITIES, DAMAGES AND EXPENSES ARISING THEREFROM.


 


INITIAL
DW L’P


 


8.12     (EXTRAHAZARDOUS
SERVICES) IF CONTRACTOR IS REQUESTED BY COMPANY TO PERFORM SERVICES IN AN URBANIZED OR ENVIRONMENTALLY SENSITIVE AREA OR UNDER
OTHER EXTRAHAZARDOUS CONDITIONS, THEN COMPANY AND CONTRACTOR SHALL AGREE ON AN INDEPENDENT COMPANY TO MONITOR THE PERFORMANCE
OF SUCH SERVICES. NOTWITHSTANDING ANYTHING TO THE CONTRARY HEREIN, IT IS FURTHER AGREED THAT, UNLESS OTHERWISE INSTRUCTED BY COMPANY,
CONTRACTOR SHALL BE DEEMED TO BE IN FULL COMPLIANCE WITH CONTRACTOR’S OBLIGATIONS AND DUTIES HEREUNDER REGARDING DENOTATION
OF EXPLOSIVES OR DISCHARGES OF SHOT POINTS BY CONTRACTOR IN THE NORMAL COURSE OF ITS OPERATIONS WHEN SUCH DENOTATIONS OR DISCHARGES
ARE OF NO GREATER QUANTITY AND AT NO LESSER DISTANCE FROM THE OBJECTS AS PROVIDED FOR BY THE DIRECTION OF AN INDEPENDENT MONITORING
COMPANY MUTUALLY AGREED UPON BY COMPANY AND CONTRACTOR. TO THE EXTENT CONTRACTOR’S PERFORMANCE CONFORMS WITH THE FOREGOING
MONITORING COMPANY’S DIRECTIONS, OR COMPANY’S INSTRUCTION, COMPANY SHALL PROTECT, DEFEND, INDEMNIFY AND HOLD HARMLESS
CONTRACTOR FROM AND AGAINST ALL THIRD PARTY CLAIMS, LIABILITIES, LOSS, EXPENSE DAMAGES, DEMANDS, CAUSES OF ACTION, JUDGEMENTS
AND SETTLEMENTS (INCLUDING COSTS OF DEFENSE AND ATTORNEY’S FEES ASSOCIATED THEREWITH) THAT ARISE OUT OF OR OCCUR AS A RESULT
OF SUCH SHOT POINTS/VIBRATOR STATIONS. THE INDEMNIFICATION SHALL APPLY WHETHER OR NOT CONTRACTOR IS CLAIMED TO BE OR IS ADJUDICATED
TO BE NEGLIGENT BY VIRTUE OF SO LOCATING SUCH SHOT POINTS/VIBRATOR STATIONS.


 


INITIAL
DW L’P


 


Page 8 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


9.      INSURANCE


 


9.1     (General)


 


The Contractor
shall, at its sole cost, maintain, so long as this Agreement remains in force, with one or more reputable insurance companies,
the following insurance:


 


9.1.1     Worker's compensation and/or
employer's liability insurance in compliance with the laws of all states in which Survey(s) is/are to be performed or where
Contractor's personnel are hired covering all employees engaged by Contractor (or its subcontractors) in such Survey(s).


 


9.1.2     Automobile public liability
insurance covering all vehicles performing Survey(s) hereunder, with limits of One Million Dollars ($1,000,000) for one or
more persons injured or killed, or property damage incurred per occurrence, combined single limit.


 


9.1.3     Comprehensive public liability
insurance covering all operations hereunder with limits of One Million Dollars ($1,000,000) for one or more persons injured
or killed in any one accident, and with property damage limits of One Million Dollars ($1,000,000) per occurrence, combined
single limit.


 


9.1.4     If aircraft are used in the
operations hereunder, Aviation Liability Insurance covering all airplanes and helicopters, whether non-owned, chartered, or
hired and furnished by Contractor (or its subcontractors) and used in the operations hereunder in an amount of not less than
One Million Dollars ($1,000,000) per occurrence combined single limit,


 


9.1.5     If
waterborne vessels are used in operations hereunder, hull and machinery insurance shall be maintained in an amount at least equal
to the market value of each vessel owned by Contractor and used in operations hereunder. In the event the vessel is time-chartered
by Contractor, then Contractor shall require the owner of the vessel to procure such insurance.


 


9.2     (Insurance
Certificates) Before any Survey(s) are commenced by Contractor hereunder, Contractor shall furnish to Company certificates
attesting the above insurance coverages to be in force and providing that Company will be given at least TEN (10) days written
notice prior to cancellation, termination or significant modification thereof and that Company should be named as additional insured.


 


9.3     (MISCELLANEOUS)
IT IS UNDERSTOOD AND AGREED THAT CONTRACTOR'S INSURANCE COVERAGE AS DETAILED IN THE FOREGOING SECTIONS SHALL AFFORD COMPANY
PROTECTION AND COVERAGE WITH RESPECT TO THOSE MATTERS COVERED BY SPECIFIC INDEMNITY AGREEMENTS EXTENDED BY CONTRACTOR ELSEWHERE
PROVIDED HEREIN AND, EXCEPT FOR WORKERS COMPENSATION INSURANCE, COMPANY SHALL BE NAMED AN ADDITIONAL INSURED PARTY UNDER SAID
POLICIES BUT ONLY TO THE EXTENT OF THE LIABILITIES ASSUMED BY CONTRACTOR UNDER THE TERMS HEREOF. ALL INSURANCE POLICIES REQUIRED
BY THIS AGREEMENT TO BE MAINTAINED BY CONTRACTOR SHALL BE ENDORSED WHEREBY CONTRACTOR'S INSURERS SHALL WAIVE THEIR RIGHTS OF SUBROGATION
AGAINST COMPANY, ENTITIES AFFILIATED WITH COMPANY AND THEIR RESPECTIVE INSURERS TO THE EXTENT OF THE LIABILITIES ASSUMED HEREIN
BY CONTRACTOR. ANY AND ALL DEDUCTIBLES OR RETENTIONS APPLICABLE TO CONTRACTOR'S INSURANCE COVERAGES SHALL BE ASSUMED BY CONTRACTOR
AT ITS SOLE EXPENSE. UNLESS PROHIBITED OR LIMITED BY APPLICABLE LAW, INSURANCE PROVIDED BY THE PARTIES IN SUPPORT OF THEIR RESPECTIVE
INDEMNITY OBLIGATIONS SET FORTH IN CLAUSE 8 ABOVE SHALL IN NO WAY SERVE TO LIMIT EACH SUCH PARTY'S INDEMNITY OBLIGATIONS. CONTRACTOR
AND COMPANY SHALL DELIVER TO EACH OTHER RESPECTIVE CERTIFICATES OF INSURANCE EVIDENCING INSURANCE COVERAGES REQUIRED UNDER CLAUSES
8.5 AND 9 OF THIS AGREEMENT.


 


INITIAL
DW L’P


 


9.4     (Subcontractors) Contractor
shall require, to the extent possible, that each of its subcontractors, if any, performing Work hereunder maintain such
insurance coverages as are required of Contractor.


 


Page 9 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


10.      COMPLIANCE
WITH LAWS/HES


 


10.1     (Laws) Contractor shall comply
with all applicable laws, rules and regulations, both federal, state and local, applicable to any Survey performed by
Contractor hereunder, and shall also comply with, observe and abide by the Health, Environment and Safety standards of any
applicable governmental agency.


 


10.2     (Health, Environment and
Safety) Contractor will perform the Survey(s) applying the most current edition of either the IAGC Land Geophysical
Operations Safety Manual or the IAGC Marine Geophysical Operations Safety Manual, as applicable, as a minimum set of
standards supplemented by both Contractor and Company HES rules and work procedures. The more stringent of Company's or
Contractor's policy and standards shall apply. Company reserves the right to intervene and consult with Contractor in
development of solutions for hazards identified in execution of the Work. Contractor will equally apply HES standards to, and
enforce compliance with all such standards, by all subcontractors of any tier, and the agents, employees or other personnel
under their control and will replace at Contractor's expense those who fail to comply.


 


10.3     (Accidents)
Contractor shall report all accidents to Company. In the event there is an accident involving damage to the property or
injury to the personnel of Contractor, Company or any third party, any environmental damage or any incidents involving media
attention, which arise out of, result from, or is in any way connected with Contractor's Work under this Agreement, all
Contractor reports shall contain factual information only and will not contain opinion, speculation or supposition as to
fault, liability or prevention. Company reserves the right to participate in the investigation of any incident or accident
resulting from the Work conducted pursuant to this Agreement.


 


11.      COMPANY
REPRESENTATIVE


 


Company shall designate
in writing a representative of Company (whether an employee of Company or a third party) to whom Contractor's Party Chief or other
representative may deliver reports and other confidential information developed from Survey(s) and from whom Contractor will receive
instructions related thereto ("Company Representative" or "Representative"). Such Representative
shall have the right to be present during the conduct of the Survey(s). Contractor agrees to accept instructions in connection
with the operations hereunder within the scope of this Agreement and the applicable Supplement from such Company Representative.
All such instructions given by the Company Representative to Contractor which relate to the Work shall be binding on Company which
will not be entitled to thereafter disavow same.


 


12.      TAXES


 


12.1     (Equipment) Contractor will be
solely responsible for all taxes, duties, rates and assessments that may be levied in respect of any vehicles, equipment,
instruments or supplies furnished by Contractor in the performance of any Survey performed hereunder.


 


12.2     (Payroll)
Contractor will be solely responsible for all payroll taxes, unemployment insurance assessments, federal and/or pension
contributions and all other payroll deductions required to be made according to law in respect of the personnel of Contractor
engaged in the performance of any of the Survey hereunder.


 


12.3     (Income)
Contractor shall be solely responsible for any and all taxes assessed against it by the government of the U.S.A. or any state
thereof having jurisdiction, which taxes are assessed against Contractor as a result of compensation earned by Contractor
hereunder and Contractor shall protect, indemnify, defend and save Company harmless from and against any such tax
assessments, as well as those described in Clauses 12.1 and 12.2 above.


 


12.4     (Sales/Use)
Notwithstanding the foregoing, Contractor shall in no event be liable for sales, value added, use, gross receipts and similar
taxes and charges assessed by any applicable government agency, as a result of any Survey conducted by Contractor under the terms
of this Agreement, even though those taxes are generally measured by revenue or income of the Contractor, as such incidental taxes
are not usually considered as "income" or "profits" taxes as those terms are generally understood in the geophysical
industry. All such sales, value added, use and similar taxes and charges shall be for the account of Company and, if paid by Contractor,
shall be reimbursed by Company under applicable provisions hereof.


 


Page 10 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


13.      COMPENSATION/CONTRACTOR'S RIGHTS


 


13.1     (Fees) The Company agrees to pay
Contractor and Contractor agrees to accept payment for the Work to be performed hereunder at the applicable rates set forth
in Supplemental Agreements.


 


13.2     (Payment) Subject to contrary
provision of any Supplement, the Contractor shall, on or before the 15th day of each month, render to Company an itemized
invoice showing the amount due for services rendered, reimbursable costs and charges incurred by Contractor on behalf of
Company hereunder during the preceding calendar month, such invoice to be accompanied in each case by supporting vouchers and
receipts. Except to the extent they are contested in good faith by Company, the Company shall, within THIRTY (30) days
following receipt of such invoice, remit payment of the undisputed portion of same in full in United States funds by check,
bank draft or money order (or bank/wire transfer) payable to Contractor at its offices (or bank account) set forth in Clause
20 or in the applicable Supplemental Agreement,


 


13.3     (Late Payment) If Company fails
to pay any properly submitted and supported invoice, or portions thereof, of Contractor within the said THIRTY (30) day
period, the unpaid amount thereof shall (unless otherwise subject to bona fide dispute), at the option of Contractor, bear
interest until paid at a rate equal to the prime rate as published in the Wall Street Journal plus two percent or such lesser
maximum rate allowed by applicable law, per month until paid.


 


13.4     (Disputed Invoices) In the event
Company has a bona fide question concerning a Contractor invoice or a portion thereof, Company shall give notice thereof to
Contractor specifying the reasons therefore within TEN (10) days after receipt of such invoice and thereafter the late
payment charges provided above shall not apply to such invoice or portion thereof in question or dispute. The Parties shall
meet in an effort to answer such questions and to resolve such disputes as promptly as possible.


 


13.5     (Effect of Payment) Payment of
any Contractor invoice by Company shall not prejudice the right of Company to protest or dispute the correctness of any
invoice or any portion thereof before the expiration of the audit period (Clause 18 below) following the end of the calendar
month during which such statement was submitted. The passage of the audit period (Clause 18 below) without protest shall
conclusively establish its correctness.


 


13.6     (Right
to Withhold Data) Contractor shall have the option, exercisable at any time, to (i) retain possession of raw data tapes containing
the geophysical data (the "Data") acquired under the terms of this Master Agreement or any Supplemental Agreement
hereto and, (ii) regardless of any other provision of this Master Agreement to the contrary, not be required to deliver said Data
to Company until such time as all fees and other charges owed by Company to Contractor under the terms hereof (other than those
which are subject to a bona fide question or dispute) are paid in full.


 


14.      INTELLECTUAL
PROPERTY


 


14.1     (Indemnity) The Contractor shall,
at its sole cost and expense, protect, defend, indemnify and save harmless Company from and against any and all claims,
demands and liabilities made against or incurred by Contractor and/or Company for the alleged infringement or
misappropriation by Contractor of any United States Letters Patent or patent rights held or licensed by Contractor or others
which arise out of the operations of Contractor under the terms hereof provided that (i) in the event such claim is received
by or demand made upon Company, Company notifies Contractor in writing of the receipt of the claim or demand or the filing of
such proceeding within TEN (10) days after the receipt of notice of such claim, demand or service of process thereof, and
(ii) Contractor is given complete control of the defense of such proceedings, including the right to defend, settle and make
adjustments in instruments, equipment, methods, software or processes utilized by Contractor to perform the Work for the
purpose of avoiding any such alleged infringement or misappropriation, provided that such adjustments do not materially and
adversely affect the quality of the Data acquired pursuant hereto.


 


14.2     (Infringement
Relief) If Contractor is prevented from performing any of its obligations hereunder by injunction or other legal
proceedings based upon any claims for alleged infringement or misappropriation of any United States Letters Patent or patent
rights, or if on account of claims of alleged patent infringement or misappropriation, Contractor shall discontinue its use
of or change instruments, equipment, methods, software or processes contemplated in this Agreement, Contractor shall, in
every such event, be relieved from performance of its obligations hereunder insofar as such nonperformance is the result of
such alleged patent infringement or misappropriation or any injunction or other legal proceeding. The Company shall be
relieved of its obligation to make payment hereunder in respect of any Survey(s) to the extent Contractor is unable to
perform same by reason of the alleged patent infringement or misappropriation claim.


 


Page 11 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


14.3     (Rights to
Intellectual Property) The Parties expressly agree that all software programs, documents, materials and other work
created, developed or performed by Contractor in the course of performance of this Agreement, including, but not limited to,
non-geophysical data, drawings, reports, designs and working papers shall be and is the exclusive property of Contractor
which shall have all rights, title and interest therein including, but not limited to, patents, copyrights, trade secrets and
any other proprietary rights. Contractor hereby grants to Company a perpetual, non-exclusive, non-transferable
royalty-free license and right to use only for the purposes of this Agreement any software programs, documents, materials or
other work delivered to Company by Contractor.


 


15.      INDEPENDENT
CONTRACTOR


 


Nothing contained in this
Agreement shall be construed so as to constitute Contractor as a general agent or employee of Company, and the exclusive management,
direction and control of the employees of Contractor and its subcontractors and the Survey(s) to be conducted under the provisions
hereof shall, subject to the right of general supervision of Company's Representative, always reside in Contractor, Company being
interested only in the results obtained. Company's right to supervise shall include the right to request, for good cause shown,
the removal and replacement (at Contractor's sole cost) of any of the personnel of Contractor or its subcontractors. Company shall
also have the right of prior approval before the transfer of any of Contractor's key personnel assigned to the Work.


 


16.      ASSIGNMENT
AND SUBCONTRACTS


 


16.1     (Subcontracts) The Contractor may
subcontract to any reputable subcontractor or subcontractors such portions of the Survey(s) to be performed hereunder as is
customary and usual in the performance of same, but Company shall in no way be held liable for payment of any monies due to
any such subcontractors. The Contractor shall, notwithstanding the subcontracting of any Survey(s) to be performed hereunder,
remain liable and responsible to Company for the proper performance of every portion of the Survey(s) subcontracted to
others.


 


16.2     (Assignments)
Subject to Clause 16.1 above, neither Party shall assign this Agreement in whole or in part without prior written consent
of the other Party except to a company which is affiliated to the assigning Party or where such assignment is the result of an
operation of law. An "Affiliate" of a Party is defined as any company or other entity which is, either currently
or resulting from any future merger, acquisition or reorganization of the affected Party, (i) owned as to at least a 51% equity
interest by the affected Party, (ii) owns the affected Party as to at least a 51% equity interest or (iii) is under common ownership
(as to at least a 51% interest) with the affected Party. As for Company, "Affiliate" shall also include those
third party entities which are contractually related to Company in the exploration or development in Area of Operations. The affected
Party shall promptly notify the other Party of any such permitted assignment.


 


16.3     (Right to
Pledge — Optional) Contractor reserves the right to pledge its receivables to be received under the terms hereof to
the financial institution which provides working capital financing to the Contractor. In the event Contractor so assigns its
receivables, such financial institution shall have no recourse against Company with regard thereto and Contractor shall
defend and indemnify Company for any loss resulting therefrom.


 


17.      FORCE
MAJEURE


 


Neither Contractor nor Company
shall be responsible for failure to perform the terms of this Agreement or any Supplemental Agreement (other than the payment
of money) when performance is hindered or prevented by strikes, lockouts, or other labor difficulty, war or acts of war, riots
or civil unrest, fire, storm, flood, earthquake, terrorism, vandalism, interference by any government authority, inclement weather
that adversely affects Data recording operations or any other cause beyond the reasonable control of the affected Party, whether
or not similar to the matters herein enumerated ("Force Majeure"). Compensation shall be payable to Contractor
for work stoppages or delays due to Force Majeure at the applicable standby rate or such other rate, if any, as may be set forth
in the applicable Supplemental Agreement or as mutually agreed upon in writing by Company and Contractor for up to THIRTY (30)
days; and if stoppage for such cause persists after said THIRTY (30) day period (i) compensation shall be at a rate agreed upon
by Company and Contractor if Company requests Contractor to continue to stand by to resume operations; or (ii) Company or Contractor
may forthwith terminate this Agreement or the affected Supplemental Agreement.


 


Page 12 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


18.      AUDIT


 


18.1     (Audit Right) Contractor
shall maintain full and complete records concerning invoices which are based on Contractor's costs or other reimbursable
billing basis in such manner and detail as to permit reasonable verification of all such charges made to Company. Company
shall have the right, at its sole cost, to audit such records at any reasonable time upon written request to Contractor for a
period of ONE (1) year from the date such costs were incurred. Items of Compensation stated in terms of fixed percentages or
fixed lump sums shall not be subject to audit under this clause. Any audit so conducted by Company hereunder shall be
directed solely to Contractor's records related only to Work performed hereunder for Company and Company payments and
reimbursements related thereto and shall not encompass Contractor's operations on behalf of any other client. Contractor
shall provide reasonable assistance and shall cooperate with Company in order to facilitate the timely performance of any
audits provided for above. No such audit shall pertain to any intellectual/property or trade secrets of Contractor or records
or periods of time which have previously been audited by Company.


 


18.2     (Audit
Results) Upon completion of any audit, Company shall pay Contractor any compensation due hereunder as shown by the audit.
Any amount by which the total payments made by Company to Contractor exceeds the amount due Contractor as shown by the audit
shall be promptly refunded to Company.


 


19.      TERM
AND RENEWAL


 


This Master Agreement is effective
from the day and year above written and will remain in effect until either Party terminates it by giving the other THIRTY (30)
day's advance written or electronically dispatched notice, However, if a Supplemental Agreement is in effect when such notice is
given, termination of the Master Agreement shall not be effective until the date of termination of such Supplemental Agreement.
This Agreement may be renewed from time to time on such terms and subject to such conditions as the Parties may in writing agree
upon.


 


20.      NOTICES


 


20.1     All notices permitted or required to
be given under the terms of this Agreement shall be in writing and shall be deemed effective upon receipt if sent by air
mail, registered or certified and return receipt requested, post prepaid, and addressed to the respective parties hereto at
their respective addresses shown below:


 


	Contractor	Company
	 	 
	
        Dawson Geophysical Company

        Attention: Mr. C, Ray Tobias

        508 W. Wall Street, Suite 800

        Midland, Texas 79701
	
        Gray Fox Petroleum Corporation

        Attention: Lawrence Pemble

        3333 Lee Parkway, Suite 600

        Dallas, Texas 75219





 


or at such other address as shall be
designated in accordance with this Notice provision. Notices given by telex, telecopier, telefax, e-mail or other electronic means,
or by commercial courier/messenger service, shall also be effective upon receipt.


 


20.2     Either Party may
change its address for notice purposes at any time upon giving written notice specifying such new address and the effective
date of such address change to the other Party, as provided above.


 


21.      APPLICABLE
LAWS/DISPUTES


 


21.1.     (Applicable Law) This Master
Agreement and all Supplemental Agreements hereto shall be interpreted and construed in accordance with the laws, both
statutory and common law, of the State of Texas, excluding only those choice-of-law provisions which would require the law of
some other jurisdiction to be applicable.


 


21.2     (Disputes)
In the event, during the term of this Master Agreement or any Supplemental Agreement, a dispute or controversy should arise
between the Parties as to the requirements and/or interpretation hereof or Contractor's performance hereunder, both Parties agree
to meet and negotiate in the utmost good faith in an attempt to satisfactorily resolve the issue(s), which is the subject of such
dispute or controversy.


 


Page 13 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


21.3     (Governing
Rules) As between the Parties, any claims, disputes and controversies arising under or in connection with this Master
Agreement or any Supplemental Agreement which cannot be resolved by mutual agreement shall, upon written notice by one Party
to the other, be submitted to arbitration in accordance with and subject to the Rules of Conciliation and Arbitration of the
American Arbitration Association.


 


21.4     (Forum
of Proceedings) All arbitration hearings held pursuant to this Clause shall be conducted in Midland, Texas or such other
location agreed upon by both Parties. The decision of the arbitration shall be (i) final and binding upon the Parties, (ii)
not appealable to any court and (iii) enforceable in any court having jurisdiction over the Party to be charged.


 


21.5     (Proceedings)
Any dispute, controversy or claim arising out of or relating to this Master Agreement, including without limitation, a dispute
related to breach, interpretation, termination or invalidity of this Master Agreement between Company and Contractor shall be
finally and exclusively settled by binding arbitration conducted in accordance with the Rules of the American Arbitration Association
("AAA") in effect as of the date of this Master Agreement. The award of the arbitrators shall be final, binding
on the Parties and not subject to appeal. The arbitral tribunal shall not award special, indirect, consequential, exemplary or
punitive damages. The arbitral tribunal may grant interim or injunctive relief or demand specific performance.


 


21.6     The
arbitration tribunal shall be composed of THREE (3) arbitrators. Each Party shall appoint ONE (1) arbitrator. If, within
THIRTY (30) days after receipt of the claimant's notification of the appointment of an arbitrator, the respondent has not
notified the claimant in writing of the name of the arbitrator it appoints, the claimant may request the AAA to appoint the
second arbitrator. The arbitrators thus appointed shall choose the third arbitrator who will act as the presiding arbitrator
of the tribunal. If within THIRTY (30) days after the appointment of the second arbitrator, the two arbitrators have not
agreed upon the choice of the presiding arbitrator, then either Party may request the AAA to appoint the presiding arbitrator
in the same way as a sole arbitrator would be appointed under Article 4 of the UNCITRAL Rules.


 


21.7     The
arbitration proceedings, including the making of the award shall take place in Midland, Texas. The arbitration shall be
administered by the AAA. The provisions of this Clause 21 shall continue in force notwithstanding the expiration or prior
termination of this Master Agreement. The award shall be final and binding on the Parties and may be entered in any court
having jurisdiction and application may be made in such court for a judicial acceptance of the award or an order of
enforcement, as the case may be.


 


22.     WAIVER


 


The rights
herein given to either Party hereto may be exercised from time to time, singularly or in combination, and the waiver of one or
more of such rights shall not be deemed to be a waiver of such rights in the future or of any one or more of the other rights which
the exercising Party may have. No waiver of any breach of a term, provision or condition of this Master Agreement or any Supplement
by one Party shall be deemed to have been made by the other Party, unless which waiver is expressed in writing and signed by an
authorized representative of such Party, and the failure of either Party to insist upon the strict performance of any term, provision
or condition of this Agreement or any Supplemental Agreement, or to exercise any option herein given, shall not be construed as
a waiver or relinquishment in the future of the same or any other term, provision, condition or option.


 


23.     DEFAULT


 


In
the event either Party hereto should, at any time during the term hereof, commit an act of bankruptcy or assign, voluntarily or
involuntarily, its assets for the benefit of its creditors or should proceedings be commenced against or by either Party under
any bankruptcy, insolvency or similar statute or should either Party fail to comply with any material term or provision hereof
(any such action or condition being hereinafter referred to as "Default") the other Party may terminate this Master Agreement,
or the appropriate Supplemental Agreement, at its option exercisable at any time after THIRTY (30) days have elapsed after giving
notice to the defaulting Party of such Default and the defaulting Party has failed, during such period, to cure such Default or
to commence such cure to the reasonable satisfaction of the other Party.


 


Page 14 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 


24.      SURVIVAL OF TERMS


 


The termination of this Agreement, or any Supplemental Agreement concluded in connection with
this Agreement, shall not release the Parties from obligations which, expressly or by their nature, survive the termination
hereof beyond such termination. In particular, and as examples and not by way of limitation, each Party shall
remain, notwithstanding the termination hereof or of any Supplemental Agreement, bound to their respective obligations
arising under Clauses 5, 7, 8, 10, 12, 13, 17, 18 and 21 above.


 


25.      INUREMENT


 


Subject to Clause 16 above, this Master Agreement shall insure to the benefit of and be binding upon the
Parties hereto and their respective successors and assigns.


 


26.      ENTIRE AGREEMENT/MODIFICATION


 


This Master Agreement with each Supplemental Agreement, as written, embodies the entire contract between
the Parties hereto with respect to the subject matter hereof and supersedes and replaces any previous agreement, oral or written,
made and entered into between the Parties hereto respecting the Survey(s) to be performed hereunder. No modification of this Master
Agreement or any Supplemental Agreement shall be valid unless in writing, referencing this Master Agreement or the applicable
Supplemental Agreement and signed by an authorized representative of both Parties.


 


27.      COUNTERPARTS


 


This Master Agreement and any Supplemental Agreement may be executed in TWO (2) or more counterpart copies,
each of which shall be deemed an original and together they shall constitute one and the same instrument. Faxed or telecopied
signature pages shall be deemed an original provided that originally signed signature pages are exchanged timely.


 


IN WITNESS WHEREOF, the Parties hereto have executed this Master Agreement as of the day and year first
above written.


 


 








 


Page 15 of 15


MASTER GEOPHYSICAL DATA ACQUISITION
AGREEMENT






    	 



    	 



    

 








		GEOPHYSICAL COMPANY	SEISMOGRAPH SURVEYS







 


508 WEST WALL, SUITE 800


MIDLAND, TEXAS 79701.5010


TELEPHONE 432.684.3000


FACSIMILE 432.684.3030


 


 


 


 


July 29, 2014


 


 


 


 









Gray Fox Petroleum Corporation


3333 Lee Parkway, Suite 600


Dallas, Texas 75219


 


Attention: Lawrence Pemble


 


Dear Mr. Pemble:


 


Enclosed please find two (2) copies of Supplemental
Agreement No.14-1 for the acquisition of approximately 22 linear miles of 2D seismic data across lands located on the Butte Valley
2D, Elko and White Pine Counties, Nevada for your review.


 


If this meets with your approval, please sign
and return a copy together with our copy of the Master Geophysical Data Acquisition Agreement for our files. If you have any questions,
please let me know.


 


Very truly yours,


 


DAWSON GEOPHYSICAL COMPANY


 


By: /s/ C. Ray Tobias


        C. Ray Tobias


        Executive Vice President & COO


 


 


CRT/BS/ng


 


Enclosure


 






    	 



    	 



    

 





SUPPLEMENTAL
AGREEMENT NO. 14-1


To


Master Geophysical Data Acquisition
Agreement (the "Master Agreement")


Dated: July 23, 2014


Between Gray Fox Petroleum
Corporation ("Company") and


Dawson Geophysical Company
("Contractor")


July 29, 2014


 


	 	1.	GENERAL



 


All geophysical operations conducted
by Contractor will be performed in accordance with the terms and conditions of this Supplemental Agreement (the "Supplement")
and the Master Geophysical Data Acquisition Agreement referenced above (the "Master Agreement").


 


Contractor
shall render Services described herein, and Company will compensate Contractor at rates specified herein. This Survey will consist
of the acquisition of approximately 22 lineal miles of2D seismic data across lands located in Elko and White Pine Counties,
Nevada as directed by Company on the Butte Valley 2D (the "Project"). The approximate commencement
date of the data acquisition should be on or before Fourth Quarter, 2014 and the work will be conducted thereafter with due diligence
in a timely manner. The above estimated date of acquisition will depend on the receipt of surface permits, mineral permits and
crew availability. Please note that Contractor cannot guarantee a commencement date of operations but will endeavor to meet timing
considerations.


 


		2.	EQUIPMENT AND PERSONNEL



 


Surveying:


Conventional and/or GPS survey
crews, consisting of one surveyor, one assistant surveyor and rovers with Trimble 4000SE GPS and/or Leica 500 and/or Leica I ,200
series receivers for static and kinematic control with laptop computers for data reduction. 4x4 survey trucks and 4-wheeler type
vehicles will be utilized as necessary.


 


Recording:


		•	1 - ARAM Aries (Cable), Geospace
                                         GSR-Cableless or Wireless (24 bit) Data Acquisition system.



		•	Sufficient ancillary test equipment.



		•	Recording equipment. 500 to 800 stations /channels.
	 	•	Vehicles and communications
equipment to provide for safe, efficient operation.



 


 


Energy Source:


Vibrator-
One set of four, Mertz Model 26/623 buggy vibrators with 62,000 pounds peak force. One spare vibrator will be provided. Vibrators
will be equipped with Pelton-VibPro electronics with VGPS. !NOVA (AHV IV) or IVI manufactured vibrators (60,000 +Peak Force) may
be substituted prior to mobilization.


 


Personnel


•    One ea- Party Manager-
Asst PM


•    One Health Safety and
Environment Officer


•    One Field Clerk


•    One Observer


•    One Truck Mechanic


•    One Vibrator Mechanic


•    One Head Linesman


•    One
Assistant Linesman


•    Two Trouble Shooters


•    Four Vibrator Operators








    	 



    	 



    

 


		3.	RECORDING
                                         PARAMETERS



 


	 	•	Total Lineal Miles:
    	22	 
	 	• 	Recording Spread: Channels    240
    Split Spread	 	 
	 	• 	Receiver Station Interval: 	110ft.	 
	 	•	Sonrce Station Interval:	110
    or 220ft.	 
	 	•	Total Receiver Points: 	1,056	 
	 	• 	Total Source Points: 	1,056
    or 528	 
	 	• 	Receivers per mi.: 	48	 
	 	• 	Sonrce Points per mi.: 	48
    or 24	 
	 	•	Record Length: 	4
    sec.	 
	 	• 	Geophones Per Station: 	6	 
	 	• 	Geophone Array: Lineal 	55
    ft.	 
	 	•	Sample Rate: 	2ms.	 
	 	• 	Vibrators per array: 	4	 
	 	• 	No.sweeps: 	4
    or 8	 
	 	•	Sweep Length: 	16
    seconds	 
	 	• 	Drill Hole Depth: 	NA	 
	 	•	Charge Size: 	NA	 


 


		4.	COMPENSATION



 


Notwithstanding anything to
the contrary, Company shall pay to Contractor, as consideration for performing the Project, the compensation set forth below, as
well as those costs for which Contractor shall be reimbursed by Company as provided in Section 5 below:


 


Recording Crew: Mobilization
I Demobilization


 


Inclusive in Turnkey Recording
Fee


 


 


Permitting and Advance
Management


 


	Permit Agent, per day: Plus accommodations	$450.00USD:	
	 	 	 
	Advance Manager, and/I or Coordinator, per day	$450.00USD	 


 


If requested by Company, cost
of Permit Agent/s or Advance Manager and Vehicle/s used in securing permits for lines or portions thereof (also applicable if any
lines permitted are subsequently abandoned, at Company's request, without completing seismic recording operations)


 







Page
2  of 6


Supplemental
Agreement No. 14-1












    	 



    	 



    

 





Data Acquisition:
Basic Turnkey data acquisition  /recording fee / lineal mile


 


Company Option:
Vibroseis and Dynamite Infill Source Effort


 


Client Option:


 


lA: 120 fold, 4 Sweeps (16 sec.+ 4 sec record)
--------------------$ 11,500.00 USD/mi.


 


1B: 120 fold, 8 Sweeps (16 sec. + 4 sec record)
-------------------$ 16,000.00 USD/mi


 


1C: 60 fold, 4 Sweeps (16
sec.+ 4 sec record) ---------------------$ 8,800.00 USD/mi


 


ID: 60 fold, 8 Sweeps (16
sec.+ 4 sec record) -------------------- $ 11,000.00 USD/mi


 


Basic Turnkey fee includes: Mobilization/Demobilization,
Dawson personnel, recording equipment, fuel, per-diem, and consumable recording supplies.


 


Terrain Related Drive
Time Compensation:


 


Please note: Vibrator
source points not in a normal, contiguous sequence and drive time between points takes more than a normal move up time, a prorated
$2,500.00 per hour compensation will be applied.


 


Not Included In Turnkey
Recording Crew Fee:


 


	•		Not included in the turnkey rate is any and all cost associated with point
I line I hazard surveying, receiver and source point surveyed positions. Please estimate $12.50 per source or receiver
point. In addition, range staking the seismic lines for BLM- NEPA & NHPA requirements is estimated at $9,500.00 USD.





	•		Not included in the turnkey rate is any and all cost associated with infill
drilling of shot points.





	•		Not included in the turnkey rate is any and all cost associated with a helicopter
to deploy and retrieve ground recording equipment. Helicopter support is not necessary based on current line locations.



	•		Not included in the turnkey rate is any and all cost associated with permits, non-negligent
damages, PPV ground motion studies, water well flow and quality testing.



 





Note: Any items requested
by Company and not listed as all inclusive in our rates will be billed to Company as a reimbursable cost.


 


Testing- Weather Related
Standby- Ambient Noise Standby:


 


Stand-by and experimental
rate, per hour................................... $2,800.00 USD


 


Downtime for permit related
problems will be charged at $2,800.00 per hour for a maximum of 10 (ten) hours per day, and is defined as any time the crew is
not recording data due to circumstances out of their control. Parameter testing during periods of time other than the initial
time spent during initial layout spread requirement, will be charged at $2,800.00 per hour.




 


Page
3 of 6


Supplemental
Agreement No. 14-1






    	 



    	 



    

 


 


Weather related downtime,
per hour......................................... $2,500.00USD


 


Company
will be invoiced at a rate of $2,500.00/hour for all weather or weather related downtime hours in excess of 10 hours
of each 30 day period or prorated part thereof, not to exceed 10 hours per day, while contractor is on location. Contractor
is on location from the time a crew has been mobilized and is ready to commence cablelgeophone layout operations until such time
that all recording equipment is off of the ground and loaded. Contractor will track and report to the Company or Company Representative
on a daily basis any weather downtime.


 


Please Note:.
A 5% ADMINISTRATIVE FEE WILL BE CHARGED ON ALL REIMBURSABLE ITEMS, UNLESS COMPENSATION ARRANGEMENTS ARE MADE PRIOR TO THE EXPENSE
BEING INCURRED BY CONTRACTOR.


 


Invoice Prepay Schedule: Invoice due 30
days prior to costs being incurred by Contractor. Cost estimates are based on most recently experienced field work.


 


PHASE I:


 


Permit Agent:
File Notice of Intent (NO!) • Develop Plan of Action (POA) - Schedule and attend scoping meeting with BLM -Natural Resource
Specialists and Authorization Officer.


Surface Permitting-
10 days@ $450.001d + $100.001d = $5,500.00 USD


Mineral Research -7
days@ $450.001d +$100.001d = $3,850.00 USD


 


GPS Geodetic Survey:


Hazard I Access I
Stake lines for Archaeology field studies. $9,500.00USD


 


NEPA / NHPA Field Studies and
report development:


Archaeology:     Class
I File Search


                              Class
III field study ($21,000.00 USD)


Biological:


Paleontological: Desk
Top Studies ($4,000.00 USD)


 


PHASE 1: Total prepay
amount ($44,000.00 USD) Amount due prior to initiating Phase I PHASE II:


 


Permit Agent: Crew support


10 days x $550.00 per day=
($5,500.00 USD)


 


GPS Survey
-Production source and receiver locations


1,056 points x $12.50 per
point= ($13,200.00USD)


 


Seismic Data Recording:


22 lineal miles x $12,000.00
I mi.= ($264,000.00 USD)


 


PHASE II: Total prepay
amount ($282,700.00 USD) Invoice due prior to recording crew arrival


 


Contractor
will use these funds to pay third-party charges associated with the Project. Actual reimbursable and recording charges will be
reconciled for either a credit back to Company or balance owed to Contractor for anything outstanding.


 
Page
                                         4 of 6


Supplemental
Agreement No. 14-1






    	 



    	 



    

 





INVOICING


 


Invoices
shall be payable by company as provided in Clause IX of the Master Agreement.


All
invoices permitted and required under the terms of this Supplemental, shall be sent to the Company at the following
address:


 


Company
Name: Gray Fox Petroleum Corp.


Attention:
Randall Newton


Address:
PO Box 3111, Houston, TX 77002


Contact
Phone Number: (713) 425-6364


Email
- accounting@grayfoxpetro.com


 


		5.	REIMBURSABLE
                                         ITEMS



 


In addition to the
compensation set forth in Section 4 above, Company shall reimburse Contractor for the following:


 


	A.		Re-freshening and/or re-surveying services and survey standby due to weather and/or
permit requirement will be invoiced as a third party charge.






	B.		All costs associated with fence and gate building for field crew and vibrator access,
as required.



	C.		All archeological, environmental and/or reclamation services as required will be invoiced
as a third party.



	E.		All costs associated with line clearance, brushing, will be invoiced as a third party.



	F.		Subject to the approval of the Company, the cost of any specialized equipment that
may be required to gain access to areas which, due to the nature of the terrain or permit requirements, are inaccessible to normal
crew equipment, the trucking and use of such.



	G.		Contractor will endeavor to use those subcontractors that have offered the most attractive
pricing and availability utilized in determining pricing for this Project.



	H.		Damage or theft to Contractor’s equipment caused livestock, farming activities
or vandalism. Excluded is all existing damage to the equipment prior to arrival of the equipment at the work site or routine damage
that the Contractor expects from normal operations such as small nich, cuts, scrapes or abrasion. Damages caused by Contractor
negligence in not taking reasonable preventative actions to protect the equipment from livestock is excluded from reimbursable
compensation by Company.



	I.		If necessary, any costs incurred for onsite security.



	J.		Any special services required to satisfy ecological, environmental, or cultural permit
compliance from government agencies.



	K.		Damages or claims to land as well as crops and other flora, livestock, fences, buildings,
water wells and other structures in or on the land, where such damages have resulted from prudently conducted operations and are
not attributed to negligence or other fault on the part of the Contractor or its employees.



	L.		Any additional equipment and/or services required to acquire seismic data. Including
associated costs for maintenance, training and repair of lease, or specialized equipment.



	M.		Any applicable sales, use or value added taxes, duties, state trucking permits, levies,
or fees on Contractor’s Services.



	N.		Rental of required safety equipment (such as H2S detectors, pipeline detectors,
traffic control, PPV monitoring etc.), and/or required to operate.



 






Page
                                         5 of 6


Supplemental
Agreement No. 14-1






    	 



    	 



    

 



 


	O.		All third party contract surveying of receiver, source, hazard and route delineation.
Survey costs for field support, resurveying, cultural flagging and avoidance.



	P.		Project specific bonding and insurance costs related to permit requirements.



	Q.		If applicable, all snow plowing, snow machine rental, maintenance and repair for surveying
and recording crew operations.



	R.		If applicable, all associated infill drilling will be a Reimbursable costs.



	S.		If required to permit or logistics requirements, all helicopter support for the recoding
                                                                              crew                                                                               will be considered a Reimbursable item.
                                                                              If                                                                               required,please estimate $5,000.00 USD per
                                                                              day.
 
 Contractor will then use
                                                                              these funds to pay third-party charges associated with the Project. Actual reimbursable charges will be reconciled for either
                                                                              a credit back to Company or balance owed to Contractor for anything outstanding.



		6.	ITEMS
                                         TO BE FURNISHED BY COMPANY



 


All available mineral lease and surface ownership information with current
permits and listed special conditions.


 


		7.	CONFLICTS



 


Any conflict between the terms of this Supplement and the Master Agreement
shall be controlled by the terms of the Master Agreement unless any terms of the Master Agreement are specifically altered by
the terms hereof.


 


		8.	TERMINATION



 


This Supplement will terminate upon the completion of the Project or as provided
for in the Master Agreement.


 


		9.	ADDITIONAL INFORMATION



 


This Supplemental Agreement No. 14-1 is executed by the Parties as of the date
shown above.


 


 


 





 






Page 6
                                                                                                       of 6


Supplemental
Agreement No. 14-1