ARMED SERVICES BOARD OF CONTRACT APPEALS 

Petition of -- ) 

) 

Volmar Construction, Inc. ) 

) 

Under Contract No. W912QR-12-C-0074 ) 

APPEARANCE FOR THE PETITIONER: 

APPEARANCES FOR THE GOVERNMENT: 

ASBCA No. 60710-910 

Richard T. Garofalo, Esq. 

Garrity, Graham, Murphy, Garofalo 

& Flinn 

East Hanover, NJ 

Thomas H. Gourlay, Jr., Esq. 

Engineer Chief Trial Attorney 

Carlton A. Arnold, Esq. 

Engineer Trial Attorney 

U.S. Army Engineer District, Louisville 

OPINION PURSUANT TO BOARD RULE l(a)(5) 

DIRECTING CONTRACTING OFFICER TO ISSUE DECISION 

Pursuant to Board Rule l(a)(5), Volmar Construction, Inc. (Volmar) petitions 

the Board to direct the contracting officer (CO) to issue a decision on its claims in 

advance of the date announced by the CO. In response, the government argues that the 

CO's decision to issue the final decision no later than 31 March 2017 is reasonable 

because the current CO has no prior knowledge of the claims and the government will 

require an outside scheduling expert to examine the delay and impact damages. 

STATEMENT OF FACTS (SOF) FOR PURPOSES OF THE PETITION 

1. On 29 September 2012, the United States Army Corps of Engineers, 

Louisville District (government) awarded Contract No. W912QR-12-C-0074 to Volmar 

to renovate and repair buildings on Joint Base McGuire-Dix-Lakehurst, New Jersey 

(gov' t ex. 1, contract at 1-6). 

2. By letter dated 19 May 2016, Volmar submitted eight claims to the CO, 

seeking money and extensions of time. Volmar previously submitted the substance of 

its claims to the CO as written demands for payment or requests for equitable 

adjustment1 as follows: $84, 191.11 for additional asbestos abatement, temporary 

1 The Board expresses no opinion as to whether the previous submittals were claims or 

requests for equitable adjustment. 
heating costs, and inadequate water flow conditions dated 29 January 2016; $663,600.00 

for extended office overhead dated 11 February 2016; $59,208.28 for kitchen 

equipment2 dated 12 February 2016; $930,584.74 for canopy modification and loss of 

electrical subcontractor dated 22 February 2016; extension of time request for smoke 

seals dated 29 February 2016; extension of time request for railings3 dated 15 March 

20164

; $516,356.63 for additional labor, material testing, and extended office overhead 

related to impacts and delays with peeling paint from the ceiling dated 21 March 20165

; 

and $41,868.06 and $34,808.08 for additional costs regarding installation of booster fans 

dated 23 February 2016 and 31March20166. (Gov't ex. 2, claim at 1-3) 

3. By letter dated 27 June 2016, Volmar modified its two extension of time 

claims by adding extended field office overhead in the amounts of $110,538.00 for the 

railings claim and $202,756.50 for the smoke seals claim7 (gov't ex. 6). 

4. By letter dated 18 July 2016, the CO issued a final decision, granting the -

$59,208.28 claim for kitchen equipment (gov't ex. 7 at 1). The government attorney 

sent a separate letter to Volmar, dated 18 July 2016, stating that the remaining seven 

CO final decisions would be issued on or before 31 March 2017 (gov't ex. 8). 

5. Pursuant to Board Rule l(a)(5), Volmar petitioned the Board, by letter dated 

23 July 2016, for an order directing the CO to issue a decision on its seven remaining 

claims no later than a reasonable time set by the Board (pet. at 4). 

DECISION 

When a CO receives a certified claim over $100,000, the Contract Disputes Act 

(CDA), 41 U.S.C. §§ 7101-7109, requires that within sixty days of receipt of the 

claim, the CO shall either (a) issue a decision or (b) notify the contractor of the time 

2 Volmar submitted a notice of appeal regarding the kitchen equipment to the Board on 

17 June 2016 and it was docketed as ASBCA No. 60634. 

3 Volmar submitted a notice of appeal regarding the smoke seals and railings time 

extensions on 17 June 2016 and it was docketed as ASBCA No. 60635. 

4 In its 19 May 2016 claim, Volmar states that this prior submittal was dated 

29 February 2016; however, the document in the record is dated 15 March 2016 

(gov't ex. 3). 

5 In its 19 May 2016 claim, Volmar states that this prior submittal was dated 15 March 

2016; however, the document in the record is dated 21 March 2016 (gov't ex. 3). 

6 In its 19 May 2016 claim, Volmar states that this prior submittal was dated 

23 February 2016; however, the document in the record is dated 31 March 2016 

(gov't ex. 3). 

7 The Board expresses no opinion as to whether these two claims were properly 

certified. 

2 
within which a decision would be issued. 41 U.S.C. § 7103(±)(2). When a CO 

receives a claim under $100,000, the CDA requires the CO to issue a decision within 

60 days "from the contracting officer's receipt of a written request from the contractor 

that a decision be rendered within that period." 41 U.S.C. § 7103(±)(1). 

In addition to the requirements of section 7103(±)(2), the CDA also requires that 

the decision of the CO on a contractor claim "shall be issued within a reasonable 

time ... taking into account such factors as the size and complexity of the claim and the 

adequacy of information in support of the claim provided by the contractor." 

41 U.S.C. § 7103(f)(3). 

Under the CDA, "[a] contractor may request the tribunal concerned to direct a 

contracting officer to issue a decision in a specified period oftime, as determined by 

the tribunal concerned, in the event of undue delay on the part of the contracting 

officer." 41 U.S.C. § 7103(f)(4). Board Rule l(a)(5) implements this section 

providing that "[i]n lieu of filing a notice of appeal under paragraph (a)(l) or (a)(2) of 

this Rule, the contractor may petition the Board to direct the contracting officer to 

issue a decision in a specified period of time as determined by the Board." 

Whether the time in which a CO states he or she will issue a decision is 

reasonable must be determined on a case by case basis. Eaton Contract Services, Inc., 

ASBCA Nos. 52686, 52796, 00-2 BCA ~ 31,039 (finding 8 months reasonable given 

the volume of documentation, number of issues and time needed to gather information 

due to relocation of personnel); Defense Systems Co., ASBCA No. 50534, 97-2 BCA 

~ 28,981 (finding 9 months reasonable when claimed amount exceeded $71 million 

and narrative portion of the claim alone exceeded 162 pages); Dillingham/ABB-SUSA, 

a Joint Venture, ASBCA Nos. 51195, 51197, 98-2 BCA ~ 29,778 (finding 14-16 

months unreasonable for a small construction claim and an impact claim that had been 

extensively analyzed and audited). 

Here, Volmar objects to the 31 March 2017 date established by the CO for 

issuing her decision as being unreasonable because the date is more than ten months 

from the submission of its 19 May 2016 claims and is approximately thirteen months 

from its original submissions. Volmar instead seeks an order from the Board to direct 

the CO to issue a decision "within a specified period of time and well before March 31, 

2017." (Pet.at2-4) 

The government maintains that 31 March 2017 is a reasonable date on which to 

issue a CO decision. The government states that the CO who will issue the decision 

has had no exposure to the issues raised in Volmar's claims and that an outside 

scheduling expert will need to be hired to examine the delay and impact damages. 

(Gov't opp'n at 2) 

3 
We find the government's arguments not wholly persuasive. While bringing on 

a CO who has had no exposure to the issues can be time-consuming, internal staffing 

matters are not one of the factors used to determine a reasonable time under the CDA. 

See Fru-Con Construction Corp., ASBCA No. 53544, 02-1BCA~31,729 (finding the 

scarcity of attorneys to assist with the review of a contracting officer's final decision is 

a matter wholly and exclusively within the control of the government). 

The government has had Volmar's original submissions for well over seven 

months and has had Volmar's claims for well over four months (SOF ~ 2). 

Furthermore, a report from an outside scheduling expert could be produced by 

mid-October 2016 by the government's own calculations. The government stated in 

its response to Volmar's petition that it would take roughly 90 days to execute a 

contract to fund and obtain the services of an outside scheduling expert. Then, it 

would take approximately 60 days or longer to produce the report. (Gov't opp'n at 2) 

Volmar's claims were dated 19 May 2016, meaning the outside scheduling expert 

report could be produced by mid-October 2016. The mid-October date does not even 

factor into account that the government received all of the impact and delay claims in 

some form before 19 May 2016 (SOF ~ 2). The government stated that the remaining 

time after the outside scheduling expert's report completion until 31 March 2017 is 

necessary to "assemble the supporting documentation, confer with technical experts 

and issue the decision" (gov't opp'n at 2). We are not persuaded that such a lengthy 

time period is required. 

Accordingly, we find the 31 March 2017 date for issuing a final decision to 

represent an undue delay. After considering all the arguments, we believe that a 

reasonable time for the CO to issue a final decision is 13 January 2017. 

CONCLUSION 

We hereby direct the CO, pursuant to 41 U.S.C. § 7103(f)(4), to issue a 

decision no later than 13 January 2017. 

4 
This order completes all necessary action by the Board. If the CO fails to 

comply with this order, such failure will be deemed a decision by the CO denying the 

claims and the contractor may appeal to this Board or sue in the United States Court of 

Federal Claims pursuant to 41 U.S.C. §§ 7103(f)(5) or 7104. 

Dated: 7 October 2016 

I concur 

Aaministrative Judge 

Vice Chairman 

Armed Services Board 

of Contract Appeals 

/ MARK N. STEMPLER 

Administrative Judge 

Acting Chairman 

Armed Services Board 

of Contract Appeals 

Administrative Judge 

Armed Services Board 

of Contract Appeals 

I certify that the foregoing is a true copy of the Opinion and Decision of the 

Armed Services Board of Contract Appeals in ASBCA No. 60710-910, Petition of 

Volmar Construction, Inc., rendered in conformance with the Board's Charter. 

Dated: 

5 

JEFFREY D. GARDIN 

Recorder, Armed Services 

Board of Contract Appeals