United States Court of Appeals

for the Federal Circuit

______________________ 

ZAFER CONSTRUCTION COMPANY, AKA ZAFER

TAAHHUT INSAAT VE TICARET A.S.,

Plaintiff-Appellant

v.

UNITED STATES,

Defendant-Appellee

______________________ 

2021-1547

______________________ 

Appeal from the United States Court of Federal Claims 

in No. 1:19-cv-00673-EGB, Senior Judge Eric G. Bruggink.

______________________ 

Decided: July 18, 2022

______________________ 

ABRAHAM GDANSKI, Gdanski Law PC, Teaneck, NJ, argued for plaintiff-appellant. Also represented by SAM

GDANSKI. 

ROBERT R. KIEPURA, Commercial Litigation Branch, 

Civil Division, United States Department of Justice, 

Washington, DC, argued for defendant-appellee. Also represented by BRIAN M. BOYNTON, STEVEN JOHN GILLINGHAM,

MARTIN F. HOCKEY, JR. 

______________________ 

Before NEWMAN, REYNA, and HUGHES, Circuit Judges.

Case: 21-1547 Document: 65 Page: 1 Filed: 07/18/2022
2 ZAFER CONSTRUCTION COMPANY v. US

HUGHES, Circuit Judge. 

Zafer Construction Company appeals a decision of the 

United States Court of Federal Claims dismissing Zafer’s 

complaint for failing to state a cause of action under Court 

of Federal Claims Rule 12(b)(6). The Court of Federal 

Claims determined that Zafer’s request for equitable adjustment is not a claim under the Contract Disputes Act

and that Zafer’s subsequent claim is time barred. Because 

Zafer’s request for equitable adjustment is a claim, we reverse and remand. 

I 

In June 2008, the United States and Zafer agreed to a 

$40 million contract to design and build water systems on 

the Bagram Air Base in Afghanistan. Zafer completed the 

project and submitted a request for equitable adjustment 

on September 10, 2013, which it timely amended on December 17, 2014. In its 167-page request, Zafer alleged that 

the government increased the cost of the project by causing 

delays and modifying the contract. Zafer’s detailed request 

sought $6.7 million and provided a breakdown of the reasons for the claimed amounts. Zafer submitted its request

“so that the parties c[ould] engage in immediate discussions and negotiations to mutually amicably resolve [its]

request.” Appx46 (request for equitable adjustment). And 

Zafer certified its request in accordance with the claim-certification requirement of 41 U.S.C. § 7103(b)(1), going beyond what is required by 48 C.F.R. § 252.243-7002(b) to 

certify mere requests for equitable adjustment.

The parties negotiated for four-and-a-half years but did

not fully resolve Zafer’s request. On February 7, 2018, 

Zafer asked to convert its request for equitable adjustment

into a claim. The contracting officer reviewed Zafer’s claim 

and determined that most of it is time barred under 

41 U.S.C. § 7103(a)(4)(A) because much of the government’s alleged conduct had transpired more than six years 

before Zafer had converted its request into a claim. 

Case: 21-1547 Document: 65 Page: 2 Filed: 07/18/2022
ZAFER CONSTRUCTION COMPANY v. US 3

Zafer sued in the Court of Federal Claims. The Court 

of Federal Claims found that Zafer’s claim had “accrued no 

later than August 1, 2011,” meaning Zafer had to have submitted a claim by August 1, 2017 for the claim to be timely. 

Appx10. Although Zafer had submitted a request for equitable adjustment in December 2014, the court determined 

that because this document “lacks a request for a final decision” and “asks for negotiations,” it is not a claim but a 

request for negotiations. Appx9–10. And because Zafer converted its request for equitable adjustment into a “proper” 

claim after the 2017 deadline, the court dismissed Zafer’s 

complaint for failure to state a cause of action upon which 

relief can be granted under the court’s Rule 12(b)(6). 

Appx10–11.

Zafer appeals. We have jurisdiction under 28 U.S.C. 

§ 1295(a)(3).

II

We review decisions to dismiss complaints under Rule

12(b)(6) de novo. Dehne v. United States, 970 F.2d 890, 892 

(Fed. Cir. 1992).

A 

The Federal Acquisition Regulation defines “claim” as

a written demand or written assertion by one of the 

contracting parties seeking, as a matter of right, 

the payment of money in a sum certain, the adjustment or interpretation of contract terms, or other 

relief arising under or relating to this contract. 

48 C.F.R. § 52.233-1(c); see Todd Constr., L.P. v. United 

States, 656 F.3d 1306, 1311 (Fed. Cir. 2011) (“[T]he definition of the term ‘claim’ in the FAR governs” the use of that 

term in the Contract Disputes Act.). The regulation further 

distinguishes claims from “routine request[s] for payment,” 

like vouchers or invoices. 48 C.F.R. § 52.233-1(c). 

Case: 21-1547 Document: 65 Page: 3 Filed: 07/18/2022
4 ZAFER CONSTRUCTION COMPANY v. US

Under the Contract Disputes Act, if a contractor’s 

claim is for more than $100,000, the contractor must certify 

that

(A) the claim is made in good faith;

(B) the supporting data are accurate and complete 

to the best of the contractor’s knowledge and 

belief; 

(C) the amount requested accurately reflects the 

contract adjustment for which the contractor 

believes the Federal Government is liable; and

(D) the certifier is authorized to certify the claim on 

behalf of the contractor.

41 U.S.C. § 7103(b)(1); see 48 C.F.R. § 52.233-1(d)(2)(iii).

Requests for equitable adjustment, on the other hand, require certification of only (A) and (B). 48 C.F.R. § 252.243-

7002(b).

In addition to these requirements, a contractor must

show that “what the contractor desires by its submissions 

is a final decision” from the contracting officer determining

whether the contractor is entitled to the claimed amount.

M. Maropakis Carpentry, Inc. v. United States, 609 F.3d 

1323, 1327–28 (Fed. Cir. 2010). We have derived this “request” requirement from 41 U.S.C. § 7103(a)(1) and 48 

C.F.R. § 33.206(a), which instruct contractors to submit 

claims “to the contracting officer for a decision.” See James 

M. Ellett Constr. Co. v. United States, 93 F.3d 1537, 1543 

& n.4 (Fed. Cir. 1996) (emphasis added); Transamerica Ins. 

Corp. v. United States, 973 F.2d 1572, 1576 (Fed. Cir. 

1992). 

To fulfill the request requirement, the contractor’s request for a final decision can be either explicit or implicit. 

Transamerica, 973 F.2d at 1576. The claim does not need 

to “be submitted in any particular form or use any particular wording.” Cont. Cleaning Maint., Inc. v. United States, 

Case: 21-1547 Document: 65 Page: 4 Filed: 07/18/2022
ZAFER CONSTRUCTION COMPANY v. US 5

811 F.2d 586, 592 (Fed. Cir. 1987). For example, a request 

for equitable adjustment can constitute a claim. Hejran

Hejrat Co. v. U.S. Army Corps of Eng’rs, 930 F.3d 1354,

1357 (Fed. Cir. 2019). And “[t]here is no necessary inconsistency between” a claim and “an expressed desire to continue to mutually work toward a claim’s resolution.” 

Reflectone, Inc. v. Dalton, 60 F.3d 1572, 1583 (Fed. Cir. 

1995).

B 

The parties appear to agree that Zafer’s December 

2014 request for equitable adjustment satisfies the definition of a “claim” in 48 C.F.R. § 52.233-1(c) and the claimcertification requirement. See Appellee’s Br. 8–10 (identifying but not disputing these requirements). At issue is 

whether Zafer satisfied the request requirement. 

Zafer argues that its December 2014 request for equitable adjustment fulfills the request requirement because

the document at length discusses Zafer’s request for money 

owed, showing that Zafer intended for the contracting officer to make a decision regarding entitlement. Zafer contends that the Court of Federal Claims’ contrary conclusion

relies on a “hyper-technical analysis” that Zafer asserts we 

have previously rejected. Appellant’s Br. 8.

The government responds that Zafer “sent clear signals” that it intended only to negotiate a contract proposal, 

not to request a final decision. Appellee’s Br. 10. In the government’s view, Zafer knew the difference between a request for equitable adjustment and a claim because Zafer

submitted a proper, but untimely, claim in December 2018.

C 

The parties suggest that the request requirement focuses on a contractor’s subjective intent. See Appellant’s 

Br. 11 (arguing that the length of the request for equitable 

adjustment evinces Zafer’s “intent for the contracting officer [to] make a decision for entitlement”); Appellee’s Br. 

Case: 21-1547 Document: 65 Page: 5 Filed: 07/18/2022
6 ZAFER CONSTRUCTION COMPANY v. US

10 (“Zafer sent clear signals that, before 2018, it sought 

only to negotiate a contract proposal and not to seek a 

COFD.”). That is incorrect. The determination focuses on 

whether, objectively, the document’s content and the context surrounding the document’s submission put the contracting officer on notice that the document is a claim

requesting a final decision. See Heyl & Patterson, Inc. v. 

O’Keefe, 986 F.2d 480, 483 (“[A] request for a final decision 

can be implied from the context of the submission.”), overruled in part on other grounds by Reflectone, 60 F.3d at 

1579 n.10.; see also Transamerica, 973 F.2d at 1576 (“[A]s 

long as what the contractor desires by its submissions is a 

final decision, that prong of the CDA claim test is met.”

(emphasis added)); Maropakis, 609 F.3d at 1328 (“A claim 

cannot be based merely on intent to assert a claim without 

any communication by the contractor of a desire for a contracting officer decision.”). 

The request requirement is not a hyper-technical requirement, and we have repeatedly rebuffed attempts to 

make it one, relying instead on a “common sense analysis.” 

Transamerica, 973 F.2d at 1579. 

In Contract Cleaning Maintenance, Inc. v. United 

States, 811 F.2d 586 (Fed. Cir. 1987), the appellant submitted letters “specif[ying] various items that . . . had [been] 

disallowed but to which the appellant claimed entitlement” 

and “express[ing] the hope that the dispute could be settled.” Id. at 592. The government argued that the letters 

were not claims because they did not “contain the requisite 

demand for payment as a matter of right.” Id. We rejected 

this argument, stating that “[w]e know of no requirement 

in the Disputes Act that a ‘claim’ must be submitted in any 

particular form or use any particular wording.” Id. “All that 

is required is that the contractor submit in writing to the 

contracting officer a clear and unequivocal statement that 

gives the contracting officer adequate notice of the basis 

and amount of the claim.” Id. We clarified that “[t]he fact 

that in those letters the appellant frequently expressed the 

Case: 21-1547 Document: 65 Page: 6 Filed: 07/18/2022
ZAFER CONSTRUCTION COMPANY v. US 7

hope that the dispute could be settled and suggested meeting to accomplish that result does not mean that those letters did not constitute ‘claims.’” Id.

In Transamerica Insurance Corp., Inc. v. United States, 

973 F.2d 1572 (Fed. Cir. 1992), the appellant had submitted a letter with a certification to the contracting officer, 

requesting equitable adjustment. Id. at 1574–75. The government argued that this letter was not a claim because it 

did not include a request for a final decision, either explicitly or implicitly. Id. at 1576. We recognized that the letter 

“did not use the explicit words ‘we request a final decision 

from the contracting officer,’” but we concluded that “it 

[wa]s clear from the language of the letter itself that” the 

appellant wanted a final decision. Id. at 1578. 

In particular, the letter “requested payment of a sum 

certain[] and gave the contracting officer adequate notice 

of the basis and the amount of the claim.” Id. We were 

“loathe to believe that . . . a reasonable contractor would 

submit to the contracting officer a letter containing a payment request after a dispute had arisen solely for the contracting officer’s information and without at the very least 

an implied request that the contracting officer make a decision as to entitlement.” Id. So we reaffirmed our holdings 

in Contract Cleaning and reiterated that “[t]here is no necessary inconsistency between the existence of a valid CDA 

claim and an expressed desire to continue to mutually work 

toward a claim’s resolution.” Id. at 1579.

And in Hejran Hejrat Co. v. United States Army Corps 

of Engineers, 930 F.3d 1354 (Fed. Cir. 2019), the appellant 

had submitted a request for equitable adjustment that specifically requested that the submission be “treated as a [request for equitable adjustment].” Id. at 1356. The 

government argued that a request for equitable adjustment cannot constitute a claim and, alternatively, that the 

appellant’s document could not be a claim because it did

not include language requesting a final decision. Id. at 

Case: 21-1547 Document: 65 Page: 7 Filed: 07/18/2022
8 ZAFER CONSTRUCTION COMPANY v. US

1357. We held that a request for equitable adjustment can 

be a claim. Id. And we reiterated that “magic words are not 

required under our cases”: “a CDA claim need not be submitted in any particular form or use any particular wording” as long as it includes “a clear and unequivocal 

statement that gives the contracting officer adequate notice of the basis and amount of the claim.” Id. (quoting 

Maropakis, 609 F.3d at 1327). We found persuasive that 

the appellant “submitted a sworn statement attesting to 

the truth of the submission, included detailed factual bases 

for its alleged losses, and claimed a sum certain based on 

the losses.” Id. at 1357–58.

While Zafer’s request for equitable adjustment does not 

explicitly request a final decision, its content and the context surrounding its submission put the contracting officer 

on notice that the document is a claim requesting a final 

decision. In the 167 pages of its request, Zafer meticulously 

alleges changes and delays caused by the government, explains the reasoning behind its allegations, and requests a 

sum certain. E.g., Appx184–85, 202. And Zafer’s certification satisfies all of the certification requirements for a

claim, which go beyond what is required for a mere request 

for equitable adjustment. Appx204; see 48 C.F.R. 

§ 243.204-71(c) (“The certification required by 10 U.S.C. 

2410(a), as implemented in the clause at 252.243-7002, is 

different from the certification required by 41 U.S.C. 

7103.”); compare 41 U.S.C. § 7103(b)(1) (claim certification 

requirement), with 48 C.F.R. § 252.243-7002(b) (request for 

equitable adjustment certification requirement). Like the 

appellant in Hejran, Zafer clearly stated the basis of its 

claim, claimed a sum certain, and submitted a sworn statement attesting to the truth of its submission.

In its request for equitable adjustment, Zafer even explicitly characterizes the request as “encompass[ing] all 

claims incurred by ZAFER as a result of changes, constructive changes, [and] delay” caused by the government. 

Appx53 (emphasis added). And it notes in the conclusion of 

Case: 21-1547 Document: 65 Page: 8 Filed: 07/18/2022
ZAFER CONSTRUCTION COMPANY v. US 9

its request that “contracting officers are required to deal 

with claims fairly.” Appx204 (emphasis added). Zafer’s request for equitable adjustment constitutes “a clear and unequivocal statement that gives the contracting officer 

adequate notice of the basis and amount of the claim,” so it 

is a claim. Cont. Cleaning, 811 F.2d at 592.

This appeal is distinct from James M. Ellett Construction Co. v. United States, 93 F.3d 1537 (Fed. Cir. 1996). 

There, the government had terminated for convenience the 

remainder of a contract and, in return, the appellant had 

submitted a settlement proposal requesting payment. Id.

at 1540. We determined that the appellant’s settlement 

proposal was a proposal, not a claim. Id. at 1543–44. We 

reasoned that “[t]he parties [had] agreed that they would 

try to reach a mutually agreeable settlement” and, “[i]f 

they were unable to do so . . . the contracting officer would 

issue a final decision.” Id. at 1544. In other words, the appellant was contractually required to propose and attempt 

to negotiate a settlement before submitting a claim. “Indeed, it [wa]s a proposal that [the appellant] contractually 

agreed to submit in the event of a convenience termination.” Id. We therefore concluded that the proposal “at the 

time of submission was not a claim because it was not submitted to the contracting officer for a decision” but rather 

for contractually required negotiations. Id. Unlike the appellant in Ellett, Zafer was not contractually required to 

propose and attempt to negotiate a settlement with the 

government before submitting a claim, so the reasoning of 

Ellett does not apply here. 

As we have repeatedly held, “[t]here is no necessary inconsistency between” a claim and “an expressed desire to 

continue to mutually work toward a claim’s resolution.” Reflectone, Inc. v. Dalton, 60 F.3d 1572, 1583 (Fed. Cir. 1995)

(alteration in original) (quoting Transamerica, 973 F.2d 

1572). In fact, one of the stated purposes of the Contract 

Disputes Act is to “induce resolution of more contract disputes by negotiation prior to litigation.” S. Rep. No. 95-

Case: 21-1547 Document: 65 Page: 9 Filed: 07/18/2022
10 ZAFER CONSTRUCTION COMPANY v. US

1118, at 1 (1978), as reprinted in 1978 U.S.C.C.A.N. 5235,

5235; see also H.R. Rep. No. 95-1556, at 5 (1978) (“The purpose of the proposed legislation as amended is to provide 

for . . . administrative and judicial procedures for the settlement of claims and disputes relating to Government contracts.”). We have warned against requirements that 

“would allow [the government] to continually . . . seek information and prolong negotiations without issuing an appealable decision” because such requirements can “delay[] 

rather than accelerat[e] any possible settlement.” Reflectone, 60 F.3d at 1582. Requirements “that allow[] the government to unilaterally designate when a submission 

becomes a ‘claim’ disrupt[] the balance of power between 

the government and contractors that the CDA sought to establish.” Id. A stringent request requirement would do exactly that. 

We recognize that contracting officers will sometimes 

face the difficult challenge of determining whether a request for equitable adjustment is also a claim. Contractors 

must choose between submitting a claim—which starts the 

interest clock but requires the contracting officer to issue a 

final decision within 60 days—and submitting a mere request for equitable adjustment—which does not start the 

interest clock but gives the contractor more time to negotiate a settlement and possibly avoid hefty legal fees. See 

Government Contract Compliance Handbook §§ 16:7, 

16:11 (5th ed. Cumulative Supplement 2021–2022). The 

overlap between these two types of documents might create 

room for gamesmanship. For example, a contractor could 

submit a document that is a claim—starting the interest 

clock—but appears to be a mere request for equitable adjustment—causing the contracting officer to not issue a final decision within the 60-day deadline and allowing 

interest to accrue for months or years. But the government 

has tools to address this challenge: The contracting officer 

can communicate to the contractor that she is going to treat 

the document as a claim and issue a final decision within 

Case: 21-1547 Document: 65 Page: 10 Filed: 07/18/2022
ZAFER CONSTRUCTION COMPANY v. US 11

60 days. Or the government can explicitly require the contractor to propose settlement terms and attempt to settle 

disputes before submitting a claim to the contracting officer for a final decision, as in Ellett. 

III

Because Zafer’s December 2014 request for equitable 

adjustment implicitly requests a final decision and therefore is a claim, we reverse the Court of Federal Claims’ contrary determination and remand for further proceedings.

REVERSED AND REMANDED

COSTS

Costs to Zafer.

Case: 21-1547 Document: 65 Page: 11 Filed: 07/18/2022