Lease Agreement between the registrant and CarrAmerica Realty Corporation



 Exhibit 10.8 
  
 * * * * * * * * * * * * * * * * * * * * 
  
 LEASE 
  
 FREMONT TECHNOLOGY PARK 
  
 * * * * * * * * * * * * * * * * * * * * 
  
 Between 
  
 INTERVIDEO, INC. 
 (Tenant) 
  
 and 
  
 CARRAMERICA REALTY CORPORATION 
 (Landlord) 
  
 NET LEASE 
  









 TABLE OF CONTENTS 
  

					
	 	  	 	  	Page


	 1.
	  	LEASE AGREEMENT	  	1
	 2.
	  	RENT	  	2
	 3.
	  	PREPARATION AND CONDITION OF PREMISES; TENANT’S POSSESSION; REPAIRS AND MAINTENANCE	  	10
	 4.
	  	SERVICES AND UTILITIES	  	12
	 5.
	  	ALTERATIONS AND REPAIRS	  	13
	 6.
	  	USE OF PREMISES	  	15
	 7.
	  	GOVERNMENTAL REQUIREMENTS AND BUILDING RULES	  	17
	 8.
	  	WAIVER OF CLAIMS; INDEMNIFICATION; INSURANCE	  	18
	 9.
	  	FIRE AND OTHER CASUALTY	  	21
	 10.
	  	EMINENT DOMAIN	  	22
	 11.
	  	RIGHTS RESERVED TO LANDLORD	  	22
	 12.
	  	DEFAULTS	  	24
	 13.
	  	LANDLORD REMEDIES	  	25
	 14.
	  	SURRENDER	  	27
	 15.
	  	HOLDOVER	  	27
	 16.
	  	SUBORDINATION TO GROUND LEASES AND MORTGAGES	  	28
	 17.
	  	ASSIGNMENT AND SUBLEASE	  	29
	 18.
	  	CONVEYANCE BY LANDLORD	  	32
	 19.
	  	ESTOPPEL CERTIFICATE	  	33
	 20.
	  	LEASE DEPOSIT	  	33
	 21.
	  	TENANT’S PERSONAL PROPERTY AND FIXTURES	  	34
	 22.
	  	NOTICES	  	34
	 23.
	  	QUIET POSSESSION	  	35
	 24.
	  	REAL ESTATE BROKERS	  	35
	 25.
	  	MISCELLANEOUS	  	35
	 26.
	  	UNRELATED BUSINESS INCOME	  	38
	 27.
	  	BUILDING RENOVATIONS	  	38
	 28.
	  	HAZARDOUS SUBSTANCES	  	39
	 29.
	  	EXCULPATION	  	41
	 30.
	  	COMMUNICATIONS AND COMPUTER LINES	  	41
	 31.
	  	OPTION TO EXTEND	  	41

  

 i 








 LEASE 
  
 THIS LEASE (the “Lease”) is dated as of October 6, 2003 (for reference purposes only) between CARRAMERICA
REALTY CORPORATION, a Maryland corporation (“Landlord”), and the Tenant as named in the schedule below (the “Schedule”). The term “Project” means the three (3)
buildings, the land appurtenant thereto (“Land”), and other improvements located thereon commonly known as “Fremont Technology Park”, located in Fremont, California. The “Premises” means that portion of
the Project leased to Tenant and described in the Schedule and outlined on Exhibit A. The building in which the Premises are located shall be referred to herein as the “Building”. The Schedule is an integral part of this
Lease. Terms defined in this Schedule shall have the same meaning throughout the Lease. 
  
 SCHEDULE 
  

	 	1.	Tenant: Intervideo, Inc., a Delaware corporation 

  

	 	2.	Premises: 46430 Fremont Boulevard, Fremont, California, as outlined on Exhibit A attached hereto 

  

	 	3.	Building: 46420-46430 Fremont Boulevard, Fremont, California 

  

	 	4.	Rentable Square Footage of the Premises: Approximately 35,069 rentable square feet 

  

	 	5.	Tenant’s Proportionate Share: 64.76% based upon a total of 54,153 rentable square feet in the Building 

  

	 	6.	Lease Deposit: Prepaid Rent equal to Twenty-Five Thousand Two Hundred Forty-Nine and 68/100 Dollars ($25,249.68) and Security Deposit equal to Thirty Thousand Five Hundred
Ninety-One and 18/100 Dollars ($30,591.18), totaling Fifty-Five Thousand Eight Hundred Forty and 86/100 Dollars ($55,840.86). 

  

	 	7.	Permitted Use: General office, warehouse, research and development and other related uses permitted under applicable Governmental Requirements (as defined in Section
5.A(4)(c) below) 

  

	 	8.	Tenant’s Real Estate Broker for this Lease: Colliers International, Inc. 

  

	 	9.	Landlord’s Real Estate Broker for this Lease: Colliers International, Inc. 

  

	 	10.	Tenant Improvements, if any: See Section 3.A and the Tenant Improvement Agreement attached hereto as Exhibit C 

  

	 	11.	Commencement Date: November 1, 2003 (but see Section 1.A(1) for provisions which may change the Commencement Date) 

  
 Rent Commencement Date: The date that is six (6) months after the
Commencement Date, as may be modified pursuant to Section 1.A(1) 
  

 i 









	 	12.	Term / Termination Date: The Term of this Lease shall be for seven (7) years commencing on the Commencement Date and expiring on the calendar day preceding the seventh
(7th) anniversary of the Commencement Date; provided, however, that if the Commencement Date shall occur on a date
other than the first day of a calendar month, the Termination Date shall be the last day of the calendar month in which the seventh (7th) anniversary of the Commencement Date occurs. 

  

	 	13.	Parking Stalls: One Hundred Twenty-Six (126) unassigned stalls, of which the five (5) spaces closest to the front door of the Premises (as reasonably designated by Landlord
and Tenant prior to the Commencement Date) shall be designated as “Reserved Spaces”, subject to applicable Governmental Requirements, including any applicable transportation management program applicable to the Project. Such Reserved
Spaces shall be designated by signs or other markings that Tenant, at its expense, shall install subject to Landlord’s approval thereof in accordance with the provisions of Section 6.B below, maintain and remove. Notwithstanding the foregoing,
Tenant acknowledges and agrees that Landlord shall have no responsibility to enforce any restrictions on the use of the Reserved Spaces by other tenants of the Project or their employees or visitors. 

  

	 	14.	Base Rent:  

  

				
	 Period

	  	Monthly
Base Rent


	 Before Rent Commencement Date
	  	$	0.00
	 Rent Commencement Date through the 12th full calendar month of the Term
	  	$	25,249.68
	 13th
through 24th full calendar month of the Term
	  	$	26,070.29
	 25th
through 36th full calendar month of the Term
	  	$	26,917.58
	 37th
through 48th full calendar month of the Term
	  	$	27,792.40
	 49th
through 60th full calendar month of the Term
	  	$	28,695.66
	 61st
through 72nd full calendar month of the Term
	  	$	29,628.27
	 73rd
through 84th full calendar month of the Term
	  	$	30,591.18

  

	 	15.	Renewal Option: One (1) option to extend for a period of five (5) years 

  

Exhibit A - PLAN OF THE PREMISES 
 Exhibit B - RULES AND REGULATIONS

 Exhibit C - TENANT IMPROVEMENT AGREEMENT 
  

 ii 








 Exhibit C-1 – APPROVED SPACE PLAN 
 Exhibit D - COMMENCEMENT DATE CONFIRMATION (see Section 1.A) 
 Exhibit E – ENVIRONMENTAL QUESTIONNAIRE

  

 iii 








 1. LEASE AGREEMENT. On the terms stated in this Lease, Landlord leases the Premises to Tenant, and
Tenant leases the Premises from Landlord, for the Term beginning on the Commencement Date and ending on the Termination Date unless extended or sooner terminated pursuant to this Lease. 
  
 A. Commencement Date. 
  
 1. The commencement date (“Commencement Date”) for this Lease is the date set forth in the
Schedule, provided that if the Substantial Completion Date (as defined in the Tenant Improvement Agreement attached as Exhibit C) does not occur on or before the Commencement Date set forth in the Schedule for any reason, then (a) this Lease
shall not be void or voidable by either party, (b) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and (c) the Commencement Date shall be revised to mean the date on which the Substantial Completion Date occurs (or
is deemed to have occurred) and the Termination Date shall be revised accordingly so that the Term (as defined in the Schedule) is unaffected by such delay. Notwithstanding the foregoing, if the Substantial Completion Date does not occur on or
before February 1, 2004 (the “Premises Delivery Deadline”), Tenant, as its sole remedy, shall have the right to cancel this Lease by giving written notice of such cancellation to Landlord at any time after the Premises Delivery
Deadline and prior to the date Landlord delivers possession of the Premises to Tenant, in which case this Lease shall be cancelled effective thirty (30) days after Landlord’s receipt of Tenant’s cancellation notice, unless Landlord
delivers possession of the Premises to Tenant within said thirty (30) day period; provided, however, that the Premises Delivery Deadline shall be extended by the number of days that the Substantial Completion Date is delayed due to any Force Majeure
Delay (as defined below). In the event of such cancellation by Tenant, neither party shall have any obligations to the other under this Lease, except for obligations arising before such cancellation and except that Landlord shall promptly refund to
Tenant all consideration received. For purposes of this Lease, the term “Force Majeure Delay” means any delay attributable to one or more of the following causes: strike, lockout or other labor disturbance, civil disturbance, fire,
flood, lightning, earthquake, or other act of God or the public enemy, war, terrorism, riot, sabotage, blockade, embargo, accident, interruption of utilities or services, inability to obtain necessary materials, supplies or labor, action or inaction
on the part of any government or regulatory body, or any other similar cause which is beyond the reasonable control of Landlord, provided, however, that the extension of the Premises Delivery Deadline by any Force Majeure Delay shall not exceed
sixty (60) days. 
  
 2. If Landlord is delayed in
completing Landlord’s Work (as defined in the Tenant Improvement Agreement) or in delivering possession of the Premises to Tenant as a result of any Tenant Delay (as defined below), (a) the Substantial Completion Date shall be deemed to have
occurred on the date the Substantial Completion Date would have occurred in the absence of such Tenant Delay, as reasonably determined by Landlord or Landlord’s architect, and (b) Tenant shall be responsible for and shall pay any costs and
expenses incurred by Landlord in connection with, or as a consequence of, any Tenant Delay. For purposes of this Lease, the term “Tenant Delay” means a delay in the Substantial Completion (as defined in the Tenant Improvement
Agreement) of Landlord’s Work or the delivery of possession of the Premises to Tenant, to the extent caused by the act, omission, neglect or failure of Tenant or any of Tenant’s agents, employees, contractors or subcontractors; provided,
however, that no Tenant Delay shall be deemed to have occurred hereunder unless and until Landlord has given written 

  

 1 








 
notice to Tenant specifying the action or inaction which Landlord contends constitutes a Tenant Delay, and Tenant Delay shall begin from the date following
said notice when Tenant could reasonably take or refrain from taking the specified action or inaction. 
  
 3. If and only if the Commencement Date is adjusted pursuant to the foregoing, then Landlord, following the Commencement Date, shall
prepare and deliver to Tenant a Commencement Date Confirmation substantially in the form attached hereto as Exhibit D that sets forth both the Commencement Date and Termination Date for this Lease. Tenant shall execute the Commencement Date
Confirmation and deliver the executed original of the same to Landlord within three (3) days after Tenant’s receipt thereof. Tenant’s failure to timely execute and return the Commencement Date Confirmation document to Landlord shall be
conclusive evidence of Tenant’s agreement with the information as set forth therein. 
  
 4. This Lease shall be a binding contractual obligation effective upon execution and delivery hereof by Landlord and Tenant,
notwithstanding the later commencement of the Lease Term. 
  
 B. Termination Date. The termination date (“Termination Date”) of this Lease is the date set forth in the Schedule. 
  
 C. Early Occupancy. During the period commencing on the date on which this Lease has been executed by
both parties and ending on the Commencement Date (the “Early Occupancy Period”), Tenant shall be permitted to enter the Premises for the purpose of installing certain trade fixtures and cabling therein and conducting any other
business which does not delay or impede Landlord’s Work, provided that (1) Tenant’s early entry does not interfere with Landlord’s performance of Landlord’s Work, (2) prior to Tenant’s entry in the Premises, Tenant shall
furnish to Landlord certificates of insurance satisfactory to Landlord evidencing Tenant’s compliance with the requirements of Section 8.C below, and (3) Tenant shall comply with the requirements of Section 5 below. Tenant’s occupancy of
the Premises during the Early Occupancy Period shall be subject to all of the terms, covenants and conditions of this Lease, except that Landlord agrees that Tenant’s obligation to pay Base Rent and Operating Cost Share Rent (as such terms are
defined in Sections 2.A(1) and 2.A(2) below) during the Early Occupancy Period shall be waived. Any delay in Landlord’s Work caused by Tenant’s early entry shall constitute a Tenant Delay. 
  
 2. RENT. 
  
 A. Types of Rent. Tenant shall pay the following Rent
in the form of a check to Landlord at the following address: 
  
 CarrAmerica Realty Corporation 
 t/a Fremont Technology Park 
 P.O. Box 642922 
 Pittsburgh, PA 15264-2922

  

 2 








 or by wire transfer as follows: 
  

			
	 Account Name:
	  	CarrAmerica Realty Corporation
	 	  	t/a Fremont Technology Park
	 Bank Name:
	  	PNC Bank
	 Transit Number:
	  	043-000-096
	 Account Number:
	  	1004339188
	 Notification:
	  	Lease Administration (CarrAmerica Realty
	 	  	Corporation re Intervideo, Inc.)
	 Telephone:
	  	(202) 729-3852

  
 or in such other
manner as Landlord may notify Tenant. 
  
 1.
Base Rent in monthly installments in advance, commencing on the Rent Commencement Date and continuing on the first day of each calendar month thereafter. Notwithstanding the foregoing, (a) Tenant shall deposit with Landlord on the date Tenant
executes and delivers this Lease the cash sum set forth in the Schedule for Prepaid Rent, which amount shall be applied by Landlord against Base Rent for the first full calendar month following the Rent Commencement Date; and (b) if the Rent
Commencement Date is a day other than the first day of a calendar month, then the Base Rent for the partial month in which the Rent Commencement Date occurs (the “Partial Lease Month Rent”) shall be calculated on a per diem basis at
the rate of Eight Hundred Forty-One and 66/100 Dollars ($841.66) per day for the number of days of such month from and including the Rent Commencement Date, and such Partial Lease Month Rent shall be payable by Tenant on the first day of the
calendar month immediately following the Rent Commencement Date. 
  
 2. Operating Cost Share Rent for each Fiscal Year during the Term of this Lease equals the sum of the following: 
  
 (a) Tenant’s Proportionate Share of Operating Costs (as defined in Section 2.C(1) below) for the applicable Fiscal Year; provided,
however, that (i) the amount payable by Tenant pursuant to this Subsection 2.A(2)(a) shall not exceed Twenty-Eight Cents ($0.27) per rentable square foot during calendar year 2003 (the “Operating Costs Cap”), provided that the
Operating Costs Cap shall be prorated for calendar year 2003 by dividing the number of days in such calendar year following the Commencement Date by 365; (ii) if, at any time during the Term, Taxes for any Fiscal Year increase by more than three
percent (3%) over the preceding Fiscal Year as a result of a “change of ownership” of all or any portion of the Project or new construction in the Project (a “Prop 13 Event”), then the Operating Costs Cap shall increase
for such Fiscal Year by Tenant’s Proportionate Share of the amount that such increase in Taxes exceeds three percent (3%); and (iii) the Operating Costs Cap (as the same may have been increased by clause (ii) above) shall increase for calendar
year 2004 and each subsequent calendar year by three percent (3%); plus 
  
 (b) Tenant’s Proportionate Share (as set forth in the Schedule) of Capital Costs and Utility Costs (as defined in Sections 2.C(4) and 2.C(5) below, respectively) for the applicable Fiscal Year (as defined in
Section 2.C(6) below), plus 
  

 3 








 Operating Cost Share Rent shall be paid to Landlord monthly in advance in an estimated amount, as more
particularly set forth in Sections 2.B through 2.D below. As used in this Lease, the term “Rent” means Base Rent, Operating Cost Share Rent and all other costs, expenses, liabilities, and amounts which Tenant is required to pay
under this Lease (“Additional Rent”), including any interest for late payment. Tenant’s agreement to pay Rent is an independent covenant, with no right of setoff, deduction or counterclaim of any kind. 
  
 B. Payment of Operating Cost Share Rent. 

 
 1. Payment of Estimated Operating Cost Share
Rent. 
  
 (a) Before the Commencement
Date and on or before April 1 of each succeeding Fiscal Year, or as soon as reasonably possible thereafter, Landlord shall give Tenant notice of its estimate of the payments to be made pursuant to Sections 2.A(2) and 2.A(3) above for such Fiscal
Year. Landlord may revise these estimates by written notice to Tenant whenever it obtains more accurate information, such as the final real estate tax assessment or tax rate for the Project, in which event subsequent monthly payments by Tenant for
such Fiscal Year shall be based upon such revised estimate. 
  
 (b) Within ten (10) days after receiving Landlord’s notice regarding the original or revised estimate of the monthly payments to be made pursuant to Sections 2.A(2) and 2.A(3) above for a particular Fiscal Year,
Tenant shall pay Landlord an amount equal to the product of such estimated monthly payments (as set forth in Landlord’s notice), multiplied by the number of months that have elapsed in the applicable Fiscal Year to the date of such payment
including the current month, minus any payments on account thereof previously made by Tenant for the months elapsed. On the first day of each month thereafter, Tenant shall pay Landlord the estimated monthly payments as set forth in Landlord’s
most recent notice, until a new estimate becomes applicable. 
  
 2. Correction of Operating Cost Share Rent. Within one hundred fifty (150) days after the close of each Fiscal Year or as soon after such 150-day period as practicable, Landlord shall deliver to Tenant a
statement of (a) Operating Costs, Utility Costs and Capital Costs for such Fiscal Year, and (b) the payments made by Tenant under Section 2.B(1) above for such Fiscal Year (the “Annual Expense Statement”). If, on the basis of any
Annual Expense Statement, Tenant owes an amount that is less than the estimated payments previously made by Tenant for the applicable Fiscal Year, Landlord, at its election, shall either promptly refund the amount of the overpayment to Tenant or, if
this Lease is still in effect, credit such excess against Tenant’s subsequent obligations to pay Operating Cost Share Rent hereunder. If, on the basis of any Annual Expense Statement, Tenant owes an amount that is more than the estimated
payments previously made by Tenant for the applicable Fiscal Year, Tenant shall pay the deficiency to Landlord within twenty (20) days after Landlord’s delivery of such Annual Expense Statement to Tenant. 
  

 4 








 C. Definitions. 
  
 1. Included Operating Costs. 
  
 (a) “Operating Costs” means any expenses, costs and disbursements of any kind other than
Utility Costs and Capital Costs, paid or incurred by Landlord in connection with the management, maintenance, operation, insurance (including the related deductibles), repair and other related activities in connection with any part of the Project
and of the personal property, fixtures, machinery, equipment, systems and apparatus used in connection therewith, including, without limitation, Taxes and the cost of providing those services required to be furnished by Landlord under this Lease.

  
 (b) If the Project contains more than one
building, then Operating Costs shall include (i) all Operating Costs fairly allocable to the Building, and (ii) a proportionate share (based on the gross rentable area of the Building as a percentage of the gross rentable area of all of the
buildings in the Project) of all Operating Costs which relate to the Project in general and are not fairly allocable to any one building in the Project. 
  
 (c) If the Project is not fully occupied during any portion of any Fiscal Year, Landlord may adjust (an “Equitable
Adjustment”) Operating Costs to equal what would have been incurred by Landlord had the Project been fully occupied. This Equitable Adjustment shall apply only to Operating Costs which are variable and therefore increase as occupancy of the
Project increases. Landlord may incorporate the Equitable Adjustment in its estimates of Operating Costs. 
  
 (d) If any tenant of the Project contracts directly with Landlord or a third party for any Utilities or services for which Tenant pays
Landlord pursuant to Section 2.A(2) above, the total costs of such Utilities or services for the Project shall be “grossed up” to reflect what those costs would have been had such tenant(s) not directly contracted for such Utilities or
services. 
  
 2. Excluded Operating Costs.
Operating Costs shall not include: 
  
 (a) costs
of installing leasehold improvements for tenants or occupants or prospective tenants or occupants of the Project; 
  
 (b) costs of capital improvements other than Included Capital Items; 
  
 (c) interest and principal payments on mortgages or any other debt costs (except as provided in Section
2.C(1) above with regard to Included Capital Items), or rental payments on any ground lease of the Project; 
  
 (d) real estate brokers’ leasing commissions; 
  

 5 








 (e) legal fees, space planner fees and advertising expenses incurred with regard to
leasing the Project or portions thereof; 
  
 (f)
legal expenses incurred in connection with disputes with tenants that solely pertain to the particular tenant or its premises (as opposed to disputes with other tenants that pertain to tenants generally or the Building, or disputes where the tenants
of the Building would receive benefits if Landlord prevails, including, without limitation, disputes in connection with attempts by Landlord to enforce rules or regulations applicable to all tenants of the Building); 
  
 (g) any cost or expenditure for which Landlord is
reimbursed, by insurance proceeds or otherwise, except by Operating Cost Share Rent; 
  
 (h) the cost of any service furnished to any office tenant of the Project which Landlord does not make available to Tenant; 

 
 (i) depreciation (except on any Included Capital Items);

  
 (j) franchise or income taxes imposed upon
Landlord, except to the extent imposed in lieu of all or any part of Taxes; 
  
 (k) legal and auditing fees incurred for the benefit of Landlord such as collecting delinquent rents, preparing tax returns and other financial statements, and audits other than those incurred in connection with the
preparation of reports required pursuant to Section 2.B above; 
  
 (l) the wages of any employee for services not related directly to the management, maintenance, operation and repair of the Project; 
  
 (m) management fees in excess of the greater of (i) three percent (3%) of the annual gross revenues for the
Project adjusted to reflect a one hundred percent (100%) occupancy of the Project with tenants paying rent at Landlord’s quoted rates, or (ii) those charged by landlords of comparable buildings in the vicinity of the Project; and 
  
 (n) fines, penalties and interest incurred by Landlord for
late payment by Landlord or violations of law. 
  

 6 








 3. Taxes. 
  
 (a) “Taxes” means any and all taxes, assessments and charges of any kind, general or
special, ordinary or extraordinary, levied against the Project, which Landlord shall pay or become obligated to pay in connection with the ownership, leasing, renting, management, use, occupancy, control or operation of the Project or of the
personal property, fixtures, machinery, equipment, systems and apparatus used in connection therewith. Taxes shall include real estate taxes, personal property taxes, sewer rents, water rents, special or general assessments, transit taxes, ad
valorem taxes, and any tax levied on the rents hereunder or the interest of Landlord under this Lease (the “Rent Tax”). Taxes shall also include all fees and other costs and expenses paid by Landlord in reviewing any Taxes and in
seeking a refund or reduction of any Taxes, whether or not the Landlord is ultimately successful. Taxes shall also include any assessments or fees paid to any business park owners association, or similar entity, which are imposed against the Project
pursuant to any Covenants, Conditions and Restrictions (“CC&R’s”) recorded against the Project and any installments of principal and interest required to pay any existing or future general or special assessments for public
improvements, services or benefits, and any increases resulting from reassessments imposed in connection with any change in ownership or new construction. 
  
 (b) For any year, the amount to be included in Taxes (i) from taxes or assessments payable in installments, shall be the amount of the
installments (with any interest) due and payable during such year, and (ii) from all other Taxes, shall at Landlord’s election be the amount accrued, assessed, or otherwise imposed for such year or the amount due and payable in such year. Any
refund or other adjustment to any Taxes by the taxing authority, shall apply during the year in which the adjustment is made. Taxes shall not include any net income (except Rent Tax), capital, stock, succession, transfer, franchise, gift, estate or
inheritance tax, except to the extent that such tax shall be imposed in lieu of any portion of Taxes. 
  
 4. Utility Costs. 
  
 (a) “Utility Costs” means the cost of all electricity, water, gas, sewers, oil and other utilities (collectively,
“Utilities”), including any surcharges imposed, serving the Project or any part thereof (but excluding the cost of electricity directly billed to Tenant or other tenants in the Project), and any amounts, taxes, charges, surcharges,
assessments or impositions levied, assessed or imposed upon the Project or any part thereof, or upon Tenant’s use and occupancy thereof, as a result of any rationing of Utilities services or restriction on the use of Utilities affecting the
Project or any part thereof, together with all expenses, costs and disbursements paid or incurred by Landlord in connection with the maintenance and repair of the Building Systems (as defined in Section 3.C(1) below). 
  
 (b) If the Project contains more than one building, then
Utility Costs shall include (i) all Utility Costs fairly allocable to the Building, and (ii) a proportionate share (based on the gross rentable area of the Building as a percentage of the gross rentable area of all of the buildings in the Project)
of all Utility Costs which relate to the Project in general and are not fairly allocable to any one building in the Project. 
  

 7 








 (c) If the Project is not fully occupied during any portion of any Fiscal Year, Landlord
may adjust Utility Costs to equal what would have been incurred by Landlord had the Project been fully occupied. Landlord may incorporate such adjustment in its estimates of Utility Costs hereunder. 
  
 (d) If any tenant of the Project contracts directly with
Landlord or a third party for electricity or any other Utilities for which Tenant pays Landlord pursuant to Section 2.A(2) above, the total costs of such Utilities services for the Project shall be “grossed up” to reflect what those costs
would have been had such tenant(s) not directly contracted for such services. 
  
 5. Capital Costs. 
  
 (a) “Capital Costs” means the costs of any capital improvements made which are intended to reduce Operating Costs or improve safety, and those made to keep the Project in compliance with Governmental
Requirements applicable from time to time or to repair or replace existing capital improvements, facilities and equipment within the Project, such as the roof membrane and resurfacing of the parking areas (collectively, “Included Capital
Items”); provided, that the costs of any Included Capital Item shall be amortized by Landlord, together with an amount equal to interest at ten percent (10%) per annum, over the estimated useful life of such item and such amortized costs
are only included in Operating Costs for that portion of the useful life of the Included Capital Item which falls within the Term, unless the cost of the Included Capital Item is less than Ten Thousand Dollars ($10,000) in which case it shall be
expensed in the year in which it was incurred. 
  
 (b) If the Project contains more than one building, then Capital Costs shall include (i) all Capital Costs fairly allocable to the Building, and (ii) a proportionate share (based on the gross rentable area of the Building as a percentage of
the gross rentable area of all of the buildings in the Project) of all Capital Costs which relate to the Project in general and are not fairly allocable to any one building in the Project. 
  
 6. Fiscal Year. “Fiscal Year” means
each calendar year during which any portion of the Term occurs (e.g., the first Fiscal Year shall be the calendar year during which the Commencement Date occurs). 
  
 D. Computation of Base Rent and Rent Adjustments. 
  
 1. Prorations. If (a) the Commencement Date is a date
other than January 1, (b) the Termination Date is a date other than December 31, (c) this Lease terminates early, or (d) the size of the Premises increases or decreases, then in each such event, the Base Rent and the Operating Cost Share Rent shall
be equitably adjusted to reflect such event on a basis reasonably determined by Landlord to be consistent with the principles underlying the provisions of this Section 2. 
  
 2. Interest Rate. Any sum due from Tenant to Landlord not paid when due shall bear interest from the
date due until paid at the lesser of ten percent (10%) per annum or the maximum rate permitted by law (the “Interest Rate”). 
  

 8 








 3. Rent Adjustments. The square footage of the Premises and the Building set forth
in the Schedule are conclusively deemed to be the actual square footage thereof, without regard to any subsequent remeasurement of the Premises or the Building. If any Operating Cost paid in one Fiscal Year relates to more than one Fiscal Year,
Landlord may proportionately allocate such Operating Cost among the related Fiscal Years. 
  
 4. Books and Records. Landlord shall maintain on a consistent basis books and records reflecting the Operating Costs, Utility Costs
and Capital Costs in accordance with sound accounting and management practices. Tenant, through its employees or a certified public accountant working on a non-contingency fee basis, shall have the right to inspect Landlord’s records at
Landlord’s applicable local office or other location designated by Landlord upon at least seventy-two (72) hours’ prior notice during normal business hours during the ninety (90) days following Landlord’s delivery of the Annual
Expense Statement to Tenant. The results of any such inspection shall be kept strictly confidential by Tenant and its agents, and Tenant and its certified public accountant must agree, in their contract for such services, to such confidentiality
restrictions and shall specifically agree that the results shall not be made available to any other tenant of the Project (and in connection with the foregoing, prior to exercising its rights hereunder, Tenant and its agents shall sign a
confidentiality agreement acceptable to Landlord). Unless Tenant sends to Landlord any written exception to an Annual Expense Statement within six (6) months following Landlord’s delivery of the Annual Expense Statement to Tenant, such Annual
Expense Statement shall be deemed final and accepted by Tenant and Tenant waives any other rights pursuant to applicable law to inspect Landlord’s books and records and/or to contest the amount of Operating Costs, Utility Costs and/or Capital
Costs due hereunder. Tenant shall pay the amount shown on any Annual Expense Statement in the manner prescribed in this Lease, whether or not Tenant takes any such written exception, without any prejudice to such exception. If Tenant makes a timely
exception, Landlord and Tenant shall use good faith efforts to resolve Tenant’s claim; provided, however, that if Tenant’s claim is not resolved within thirty (30) days after it is furnished to Landlord, Landlord shall cause an independent
certified public accountant selected by Landlord (and subject to Tenant’s reasonable approval) to issue a final and conclusive resolution of Tenant’s exception. Tenant shall pay the cost of such certification unless Landlord’s
original determination of annual Operating Costs, Utility Costs and Capital Costs overstated the amounts thereof, in the aggregate, by more than five percent (5%), in which event Landlord shall pay the cost of such certification and will not include
such cost in any Operating Costs a share of which is payable by Tenant. 
  
 5. Miscellaneous. So long as Tenant is in default of any monetary obligation under this Lease, Tenant shall not be entitled to any refund of any amount from Landlord. If this Lease is terminated for any reason
prior to the annual determination of Operating Cost Share Rent, either party shall pay the full amount due to the other within fifteen (15) days after Landlord’s notice to Tenant of the amount when it is determined. Landlord may commingle any
payments made with respect to Operating Cost Share Rent, without payment of interest. 
  
 E. Additional Rent Upon Default by Tenant. Landlord and Tenant acknowledge that to induce Tenant to enter into this Lease, and in
consideration of Tenant’s agreement to perform all of the terms, covenants and conditions to be performed by Tenant under this Lease, as and when performance is due during the Term, Landlord has incurred (or will 

  

 9 








 
incur) significant costs, including, without limitation, the following: (i) expenditures incurred in connection with the performance of Landlord’s Work,
(ii) commissions to Landlord’s and/or Tenant’s real estate broker, (iii) attorneys’ fees and related costs incurred and/or paid by Landlord in connection with the negotiation and preparation of this Lease, and/or (iv) the rent
abatement granted to Tenant during the Early Occupancy Period and the period prior to the Rent Commencement Date (collectively, the “Inducements”). Landlord and Tenant further acknowledge that Landlord would not have granted the
Inducements to Tenant but for Tenant’s agreement to perform all of the terms, covenants, conditions and agreements to be performed by it under this Lease for the entire Term, and that Landlord’s agreement to incur such expenditures and
grant such concessions is, and shall remain, conditioned upon Tenant’s faithful performance of all of the terms, covenants, conditions and agreements to be performed by Tenant under this Lease for the entire Term. Accordingly, if a monetary
default by Tenant shall occur hereunder (after any applicable notice and cure period), Landlord shall be relieved of any unfulfilled obligation to grant Inducements hereunder, or to incur further expenses in connection therewith, and Tenant shall
pay, as liquidated damages for Landlord’s granting the Inducements and not as a penalty, within ten (10) days after the occurrence of the default, as Additional Rent, the unamortized amount of those Inducements incurred or granted prior to the
date of the default (the “Pre-Default Inducements”). Landlord may or, at Tenant’s request, shall, after the occurrence of a default, forward a statement to Tenant setting forth the amount of the Pre-Default Inducements, but the
failure to deliver such a statement shall not be or be deemed to be a waiver of the right to collect the Pre-Default Inducements or to extend the date upon which such amount shall be due and payable. For purposes of this Section 2.E, the unamortized
amount of the Pre-Default Inducements shall equal the remaining principal component, measured on the date of the default, of a level-payment amortization over the initial Term of this Lease of a principal amount equal to the Pre-Default Inducements,
including interest at the rate of twelve percent (12%) per annum. Notwithstanding the foregoing, Landlord agrees that it will seek to enforce its right to recover Pre-Default Inducements only in connection with a bankruptcy of Tenant where this
Lease is rejected or deemed rejected under Section 362 of the Code. 
  
 3. PREPARATION AND CONDITION OF PREMISES; TENANT’S POSSESSION; REPAIRS AND MAINTENANCE. 
  
 A. Condition of Premises. 
  
 1. Except for Landlord’s Work and as provided in Section 3.A(2) below, Landlord is leasing the Premises to Tenant “as is”,
without any obligation to alter, remodel, improve, repair or decorate any part of the Premises and without any express or implied representations or warranties of any kind, including, without limitation, any representation or warranty regarding the
condition of the Premises, the Building or the Project or the suitability of any of the foregoing for the conduct of Tenant’s business. 
  
 2. The Building Systems (as defined in Section 5.B below) shall be in good working condition as of the Commencement Date. Landlord, at
Landlord’s cost, shall repair any defects in the Building Systems of which Tenant gives Landlord written notice within ninety (90) days after the Commencement Date. 
  

 10 








 B. Tenant’s Possession. Tenant’s taking possession of any portion of the
Premises shall be conclusive evidence that the Premises were in good order, repair and condition, except as to defects or conditions of which Tenant gives written notice within ten (10) days after taking possession, and except as to defects in the
Building Systems, which shall be governed by Section 3.A(2) above. 
  
 C. Repairs and Maintenance. 
  
 1. Tenant’s Obligations. Except to the extent of Landlord’s obligations under Section 3.C(2) below, Tenant shall, throughout the Term at its expense, make all repairs necessary to keep the Premises,
Tenant’s fixtures and personal property, in good order, condition and repair and in compliance with all applicable Governmental Requirements. Tenant’s repair, maintenance and replacement obligations shall be performed under the supervision
and subject to the prior approval of Landlord, and within any reasonable period of time specified by Landlord, and shall include, without limitation, all plumbing and sewage facilities within the Premises, fixtures, interior walls and ceiling,
floors, windows (including the repairing, resealing, cleaning and replacing of both interior and exterior windows), doors, entrances, plate glass, showcases, skylights, all electrical facilities and equipment, including lighting fixtures, lamps,
fans and any exhaust equipment and systems, electrical motors and all other appliances and equipment of every kind and nature located in, upon or about the Premises, except that the repair and maintenance of any mechanical, electrical or other
systems (e.g., HVAC, life safety or automatic fire extinguisher/sprinkler system) (collectively, the “Building Systems”) that do not exclusively serve the Premises shall be Landlord’s responsibility as provided in
Section 3.C(2) below. Tenant shall also be responsible for all pest control within the Premises, and for all trash removal and disposal from the Premises. With respect to any HVAC systems that exclusively serve the Premises, Tenant shall obtain HVAC
systems preventive maintenance contracts with quarterly service in accordance with manufacturer recommendations, which shall be subject to the reasonable prior written approval of Landlord and paid for by Tenant, and which shall provide for and
include replacement of filters, oiling and lubricating of machinery, parts replacement, adjustment of drive belts, oil changes and other preventive maintenance, including annual maintenance of duct work, interior unit drains and caulking of sheet
metal, and recaulking of jacks and vents on an annual basis. Tenant shall have the benefit of all warranties available to Landlord regarding the equipment in such HVAC systems. Alternatively, Landlord may elect to perform all or some of the
foregoing repairs and maintenance itself, at Tenant’s expense, to the Building Systems. Landlord may also perform any maintenance or repairs itself, at Tenant’s expense, to the extent Tenant fails to perform such maintenance or repairs as
required herein. At the expiration or earlier termination of this Lease, or Tenant’s right to possession, Tenant shall return the Premises to Landlord in the condition required under Section 14 below. 
  
 2. Landlord’s Obligations. Except as otherwise
provided in Section 9 below, Landlord agrees to make all necessary repairs to (a) the structural parts of the Building, which structural parts include only the foundation and subflooring of the Building and the structural condition of the roof, the
exterior walls of the Building (but excluding the interior surfaces of exterior walls and exterior and interior of all windows, doors, ceiling and plate glass, which shall be maintained and repaired by Tenant) and the structural components of any
interior walls, (b) the roof membrane, and (c) the common areas of the Project and any Building Systems that do not exclusively serve the Premises, and to maintain the same in reasonably good order 

  

 11 








 
and condition, subject to inclusion of the costs thereof in Operating Costs; provided, however, that subject to the provisions of Section 8.F below, any
damage arising from the acts of Tenant or Tenant’s officers, employees, agents or authorized representatives shall be repaired by Landlord at Tenant’s sole expense, and Tenant shall pay Landlord, on demand, the cost of any such repair.
Landlord may also, but shall not be required to, enter the Premises at all reasonable times to make such repairs, alterations, improvements or additions to the Premises or to the Project or to any equipment located in the Project as Landlord shall
desire or deem necessary or as Landlord may be required to do by governmental or quasi-governmental authority or court order or decree. Subject to the provisions of Section 8.F below, the cost of any repairs made by Landlord on account of
Tenant’s default, or on account of the misuse or neglect by Tenant or Tenant’s officers, employees, agents or authorized representatives anywhere in the Project, shall constitute Additional Rent payable by Tenant on demand. As a condition
precedent to all of Landlord’s repair and maintenance obligations under this Lease, Tenant must have notified Landlord of the need of such repairs or maintenance. Tenant hereby waives any and all rights under and benefits of subsection 1 of
Section 1932 and Sections 1941 and 1942 of the California Civil Code and any similar or successor law, statute or ordinance now or hereafter in effect regarding Tenant’s right to make repairs and deduct the cost of such repairs from the Rent
due under this Lease. 
  
 4. SERVICES AND UTILITIES. Tenant
shall promptly pay, as the same become due, all charges for water, gas, electricity, telephone, sewer service, waste pick-up and any other utilities, materials and services furnished directly to or used by Tenant on or about the Premises during the
Term, including, without limitation, (i) meter, use and/or connection fees, hook-up fees, or standby fees, and (ii) penalties for discontinued interrupted service. If any utility service is not separately metered to the Premises, then Tenant shall
pay to Landlord, through Tenant’s payment of Utility Costs above, Tenant’s Proportionate Share of the cost of such utility service. However, (a) if Landlord reasonably determines that Tenant is using a disproportionate amount of any
utility service (whether or not separately metered), then Landlord, at its election, may (1) periodically charge Tenant, as Additional Rent, a sum equal to Landlord’s reasonable estimate of the cost of Tenant’s excess use of such utility
service, and/or (2) install, at Tenant’s expense, a separate meter to measure the utility service supplied to the Premises, and (b) if Landlord reasonably determines that Tenant is using a disproportionate share of the electrical capacity
available for the Building or Project (i.e., electrical usage in excess of that which would typically be used for general office purposes), then, in addition to the foregoing, Landlord may install, at Tenant’s expense, additional
equipment to increase the electrical capacity for the Building or Project to offset excess electrical usage by Tenant. Any interruption or cessation of utilities resulting from any causes, including any entry for repairs pursuant to this Lease, and
any renovation, redecoration or rehabilitation of any area of the Project, shall not render Landlord liable for damages to either person or property or for interruption or loss to Tenant’s business, nor be construed as an eviction of Tenant,
nor work an abatement of any portion of Rent, nor relieve Tenant from fulfillment of any covenant or agreement hereof; provided, however, that if (x) an interruption of the Project services prevents Tenant from occupying all or a material portion of
the Premises for the Permitted Use for a period of at least five (5) consecutive days and (y) such interruption was caused by the sole active negligence or willful misconduct of Landlord, its agents or employees, then monthly Rent shall thereafter
be proportionately abated during the period of such interruption. Nothing in this Section 4 shall limit the parties’ rights and obligations under Section 9 hereof, in the event of a casualty affecting the Building or Premises. 

  

 12 








 
Landlord shall make commercially reasonable efforts to give Tenant at least forty-eight (48) hours’ prior written notice of any scheduled interruption
in Project services to the Premises. 
  
 5. ALTERATIONS AND
REPAIRS. 
  
 A. Landlord’s Consent
and Conditions. 
  
 1. Except for Minor
Alterations (as defined below), Tenant shall not make any improvements or alterations to the Premises (the “Work”) without in each instance submitting plans and specifications for the Work to Landlord and obtaining Landlord’s
prior written consent. Tenant shall pay Landlord’s standard charge (or, if Landlord does not have a standard charge, then Landlord’s actual costs incurred) for review of all of the plans and all other items submitted by Tenant. Landlord
will be deemed to be acting reasonably in withholding its consent for any Work which (a) impacts the base structural components or the Building Systems, (b) impacts any other tenant’s premises, (c) is visible from outside the Premises, or (d)
would utilize building materials or equipment which are inconsistent with Landlord’s standard building materials and equipment for the Building. 
  
 2. Landlord’s approval shall not be required for Work on the interior of the Premises costing less than Five Thousand Dollars
($5,000.00) per project (“Minor Alterations”), provided that (a) Landlord would not have the right to reasonably withhold consent to the Work pursuant to clauses (a) through (d) of Section 5.A(1) above; and (b) Tenant provides
Landlord with written notice of such Minor Alteration, which shall include a copy of any governmental permits required to complete such Minor Alteration, prior to commencing construction of such Minor Alteration. 
  
 3. Tenant shall pay for the cost of all Work, including the
cost of any and all approvals, permits, fees and other charges which may be required as a condition of performing such Work. 
  
 4. The following requirements shall apply to all Work: 
  
 (a) Prior to commencement, Tenant shall furnish to Landlord building permits, certificates of insurance
satisfactory to Landlord, and, at Landlord’s request, security for payment of all costs if Landlord reasonably determines that such security is needed. 
  
 (b) Tenant shall perform all Work so as to maintain peace and harmony among other contractors serving the Project and shall avoid
interference with other work to be performed or services to be rendered in the Project. 
  
 (c) The Work shall be performed in a good and workmanlike manner, meeting the standard for construction and quality of materials in the
Building, and shall comply with all insurance requirements and all applicable laws, ordinances, regulations or requirements of the United States of America, the State of California, or the ordinances, regulations or requirements of the local
municipal or county governing body or other lawful authorities having jurisdiction over the Project, including, without limitation, any such laws, ordinances, regulations or requirements relating to hazardous materials or substances, as those


  

 13 








 
terms are defined by applicable laws now or hereafter in effect (collectively, “Governmental Requirements”). 
  
 (d) Tenant shall perform all Work so as to minimize or
prevent disruption to other tenants, and Tenant shall comply with all reasonable requests of Landlord in response to complaints from other tenants. 
  
 (e) Tenant shall perform all Work in compliance with any “Policies, Rules and Procedures for Construction Projects” which may
be in effect at the time the Work is performed. 
  
 (f) All Work shall be performed only by contractors or mechanics approved by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed; provided, however, that (i) Landlord may, in its sole discretion, specify
engineers, general contractors, subcontractors, and architects to perform work affecting the Building Systems; and (ii) if Landlord consents to any Work that requires work to be performed outside the Premises, Landlord may elect to perform such work
at Tenant’s expense. 
  
 (g) Tenant shall
permit Landlord to (i) inspect all Work during the progress thereof, (ii) with respect to any Work described in clauses (a) through (d) of Section 5.A(1) above, supervise the Work, and (iii) require corrections of faulty construction or any material
deviation from the plans for such Work as approved by Landlord; provided, however, that no such inspection shall be deemed to create any liability on the part of Landlord, or constitute a representation by Landlord or any person hired to perform
such inspection that the work so inspected conforms with such plans or complies with any Governmental Requirements, and no such inspection shall give rise to a waiver of, or estoppel with respect to, Landlord’s continuing right at any time or
from time to time to require the correction of any faulty work or any material deviation from such plans. 
  
 (h) If Landlord supervises any portion of the Work as described in subparagraph (g) above, Landlord may charge a supervisory fee not to
exceed three percent (3%) of labor, material, and all other costs of the Work which Landlord has the right to and does supervise to compensate Landlord for its review of plans and its management and supervision of the progress of the work.

  
 (i) Upon completion, Tenant shall furnish
Landlord with contractor’s affidavits and full and final statutory waivers of liens, as-built plans and specifications, and receipted bills covering all labor and materials, and all other close-out documentation related to the Work, including
any other information required under any “Policies, Rules and Procedures for Construction Projects” which may be in effect at the time. 
  
 B. Repairs. If any part of the Building Systems shall be damaged during the performance of the Work, Tenant shall promptly notify
Landlord, and Landlord may elect to repair such damage at Tenant’s expense. Alternatively, Landlord may require Tenant to repair such damage at Tenant’s sole expense using contractors approved by Landlord. 
  
 C. No Liens. Tenant has no authority to cause or
permit any lien or encumbrance of any kind to affect Landlord’s interest in the Project; any such lien or 

  

 14 








 
encumbrance shall attach to Tenant’s interest only. If any mechanic’s lien shall be filed or claim of lien made for work or materials furnished to
Tenant, then Tenant shall at its expense within ten (10) days thereafter either discharge or contest the lien or claim. If Tenant contests the lien or claim, then Tenant shall (i) within such ten (10) day period, provide Landlord adequate security
for the lien or claim, (ii) contest the lien or claim in good faith by appropriate proceedings that operate to stay its enforcement, and (iii) pay promptly any final adverse judgment entered in any such proceeding. If Tenant does not comply with
these requirements, Landlord may discharge the lien or claim, and the amount paid, as well as attorney’s fees and other expenses incurred by Landlord, shall constitute Additional Rent payable by Tenant on demand. 
  
 D. Ownership of Improvements. All Work as defined in
this Section 5, partitions, related hardware and all other improvements and all fixtures, except trade fixtures, constructed in the Premises by either Landlord or Tenant, (i) shall become Landlord’s property upon installation without
compensation to Tenant, unless Landlord consents otherwise in writing, and (ii) shall, at Landlord’s option, either (a) be surrendered to Landlord with the Premises at the termination of this Lease or of Tenant’s right to possession, or
(b) be removed in accordance with Section 14 below (unless Landlord at the time it gives its consent to the performance of such construction expressly waives in writing the right to require such removal). 
  
 6. USE OF PREMISES. 
  
 A. Limitation on Use. Tenant shall use the Premises
only for the Permitted Use stated in the Schedule and Tenant shall not use or permit the Premises or the Project to be used for any other purpose or purposes whatsoever without the prior written consent of Landlord, which may be withheld in
Landlord’s sole discretion. Tenant shall not allow any use of the Premises which will negatively affect the cost of coverage of Landlord’s insurance on the Project. Tenant shall not allow any inflammable or explosive liquids or materials
to be kept on the Premises. Tenant shall not allow any use of the Premises which would cause the value or utility of any part of the Premises to diminish or would interfere with any other tenant or with the operation of the Project by Landlord.
Tenant shall not permit any nuisance or waste to occur in, on, or about the Project, or allow any offensive noise or odor in or around the Project. At the end of each business day, or more frequently if necessary, Tenant shall deposit all garbage
and other trash (excluding any inflammable, explosive and/or hazardous materials) in trash bins or containers approved by Landlord in locations designated by Landlord from time to time. If any governmental authority shall deem the Premises to be a
“place of public accommodation” under the Americans with Disabilities Act (“ADA”) or any other comparable law as a result of Tenant’s use, Tenant shall either modify its use to cause such authority to rescind its
designation or be responsible for any alterations, structural or otherwise, required to be made to the Building or the Premises under such laws. 
  
 B. Signs. Tenant shall not place on any portion of the Premises any sign, placard, lettering, banner, displays, graphic, decor or
other advertising or communicative material which is visible from the exterior of the Premises without Landlord’s prior written approval; provided, however, that Tenant shall have the right to install one (1) sign identifying Tenant on the
rounded façade above the front door of the Premises. The material, typeface, graphic format and proportions of Tenant’s sign, as well as the precise location of such sign, shall 

  

 15 








 
be subject to Landlord’s approval, which shall not be unreasonably withheld, and any approval required under Governmental Requirements. Any signs
approved hereunder shall strictly conform to all Governmental Requirements, any CC&R’s recorded against the Project, and Landlord’s signage standards in effect at the time, and shall be installed and removed at Tenant’s expense.
Tenant, at its sole expense, shall maintain such signs in good condition and repair during the Term. Prior to the expiration or earlier termination of this Lease, Tenant at its sole cost shall remove all of its exterior signage and repair any and
all damage caused to the Building and/or Project (including and fading or discoloration) by such signs and/or the removal of such signs from the Building and/or Project. 
  
 C. Parking. Subject to the provisions of Item 13 of the Schedule, Tenant shall have the non-exclusive
right to park in the Project’s parking facilities in common with other tenants of the Project upon terms and conditions, as may from time to time be established by Landlord. Tenant agrees not to overburden the parking facilities (i.e.,
use more than the number of unassigned parking stalls indicated on the Schedule) and agrees to cooperate with Landlord and other tenants in the Project in the use of the parking facilities. Landlord reserves the right in its discretion to determine
whether the parking facilities are becoming crowded and to allocate and assign parking passes among Tenant and the other tenants in the Project. Landlord shall have the right to charge Tenant the portion that Landlord deems allocable to Tenant of
any charges (e.g., fees or taxes) imposed by the Regional Air Quality Control Board or other governmental or quasi-governmental agency in connection with the parking facilities (e.g., in connection with operation or use of the parking
facilities). Landlord shall not be liable to Tenant, nor shall this Lease be affected, if any parking is impaired by (or if any parking charges are imposed as a result of) any moratorium, initiative, referendum, law, ordinance, regulation or order
passed, issued or made by any governmental or quasi-governmental body. Tenant’s continued right to use the parking spaces is conditioned upon Tenant abiding by all rules and regulations which are prescribed from time to time for the orderly
operation and use of the parking facility where the parking passes are located, including any sticker or other identification system established by Landlord, Tenant’s cooperation in seeing that Tenant’s employees and visitors also comply
with such rules and regulations and Tenant not being in default under this Lease. Landlord specifically reserves the right to change the size, configuration, design, layout and all other aspects of the Project parking facility at any time and Tenant
acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of Rent under this Lease, from time to time, close-off or restrict access to the Project parking facility for purposes of permitting or
facilitating any such construction, alteration or improvements. Landlord may delegate its responsibilities hereunder to a parking operator in which case such parking operator shall have all the rights of control attributed hereby to the Landlord.
The parking passes rented by Tenant pursuant to this Section 6.C are provided to Tenant solely for use by Tenant’s own personnel and such passes may not be transferred, assigned, subleased or otherwise alienated by Tenant without
Landlord’s prior approval. 
  
 D.
Prohibition Against Use of Roof and Structure of Building. 
  
 1. Tenant shall be prohibited from using all or any portion of the roof of the Building or any portion of the structure of the Building during the Term of this Lease (or any extensions thereof) for any purposes
(including without limitation for the installation, maintenance and repair of a satellite dish and/or other telecommunications equipment), without 

  

 16 








 
Landlord’s prior written consent, which Landlord may withhold in its sole and absolute discretion. Notwithstanding the foregoing, Landlord shall grant
Tenant with reasonable access to the roof of the Building as may be reasonably necessary to allow Tenant to perform its HVAC and other maintenance obligations hereunder, provided that such access shall be subject to any reasonable rules and
restrictions that Landlord may impose from time to time. In addition, Tenant may, subject to Landlord’s reasonable prior written consent, use the roof for the installation of a non-revenue producing satellite dish to service Tenant’s
business in the Premises. Landlord has made no representations or promise as to the suitability or effectiveness of any part of the roof for Tenant’s proposed use, or as to any Governmental Requirements applicable to Tenant’s proposed use.

  
 2. Tenant shall submit to Landlord, with any
request for consent of any rooftop equipment, plans and specifications therefor, which must include, without limitation, the design, size and features of the rooftop equipment and mounting structure, floor and power load requirements, cabling
installations, the means of affixing or mounting the rooftop equipment, and the means of connecting the rooftop equipment to the Building’s electrical system and to the Premises. Tenant acknowledges and agrees that, if Landlord consents to
Tenant’s use of any portion of the roof of the Building, such use shall be non-exclusive and subject to Landlord’s approval of location, plans and installation pursuant to Section 5 of this Lease and such rules and regulations as Landlord
may prescribe, including, without limitation, with regard to (a) the location, size, type and methods of installation of the proposed rooftop equipment, (b) requirements to prevent electrical, electromagnetic, radio frequency or other interference
with other telecommunication equipment on or about the Building, (c) rooftop space availability, (d) restrictions on penetration of the roof surface, (e) rooftop access rights, and (f) removal requirements upon the expiration or earlier termination
of this Lease. 
  
 3. Nothing herein shall limit
or restrict Landlord’s rights under Section 11.N, or require Landlord to obtain Tenant’s consent prior to exercising such rights. 
  
 7. GOVERNMENTAL REQUIREMENTS AND BUILDING RULES. 
  
 A. Compliance in Premises. Tenant shall, at its sole cost and expense, (1) comply with all Governmental Requirements; with any
occupancy certificate issued for the Premises; and with the provisions of all recorded documents affecting the Premises, insofar as any thereof relates to or affects the condition, use or occupancy of the Premises; and (2) take all proper and
necessary action to cause the Premises, including any repairs, replacements, alterations and improvements thereto, to be maintained, constructed, used and occupied in compliance with applicable Governmental Requirements, including any applicable
code and ADA requirements, whether or not such requirements are based on Tenant’s use of the Premises, and further to assume all responsibility to ensure the Premises’ continued compliance with all Governmental Requirements, including
applicable code and ADA requirements, throughout the Term. Tenant shall be responsible, at its sole cost and expense, to make all alterations to the Premises as are required to comply with the governmental rules, regulations, requirements or
standards described in this Section 7.A. The judgment of any court of competent jurisdiction or the admission of Tenant in any judicial action, regardless of whether Landlord is a party thereto, that Tenant has violated any of said governmental
measures, shall be conclusive of that fact as between Landlord and Tenant. 
  

 17 








 B. Compliance in Common Areas. Subject to reimbursement as an Operating Cost as
provided in Section 2 above, Landlord shall perform any work required under any applicable Governmental Requirements, including the ADA, to be performed in the common areas of the Project, except that Tenant shall be solely responsible for all such
compliance work which is required as a result of Tenant’s use or activities or which relate to the initial Tenant Improvements or Tenant’s proposed alterations or repairs. With respect to any code compliance work required outside the
Premises for which Tenant is responsible hereunder, Landlord shall have the right to perform such work, or require that Tenant perform such work with contractors, subcontractors, engineers and architects approved by Landlord; and if Landlord elects
to perform such work outside the Premises, Tenant shall reimburse Landlord for the cost of such work within ten (10) days following receipt of invoices therefor. Landlord makes no representations or warranties regarding whether the Project or the
Premises complies with applicable Governmental Requirements as of the date of this Lease. 
  
 C. Rules and Regulations. Tenant shall also comply with all reasonable rules for the Project which may be established and amended
from time to time by Landlord, so long as same do not materially diminish or burden Tenant’s rights under this Lease beyond what is set forth in the current Rules and Regulations attached hereto. The present rules and regulations are contained
in Exhibit B. Failure by another tenant to comply with the rules or failure by Landlord to enforce them shall not relieve Tenant of its obligation to comply with the rules or make Landlord responsible to Tenant in any way. Landlord shall use
reasonable efforts to apply the rules and regulations uniformly with respect to Tenant and any other tenants in the Project under leases containing rules and regulations similar to this Lease. If Tenant performs alterations or repairs, Tenant shall
comply with the provisions of Section 5 of this Lease. 
  
 8.
WAIVER OF CLAIMS; INDEMNIFICATION; INSURANCE. 
  
 A. Waiver of Claims. Neither Landlord nor the other Indemnitees (as defined below) shall be liable to Tenant or to any Tenant Parties (as defined below), and Tenant waives all claims against Landlord and such other Indemnitees, for
any injury to or death of any person or for loss of use of or damage to or destruction of property in or about the Premises or Project by or from any cause whatsoever, including without limitation, earthquake or earth movement, gas, fire, oil,
electricity or leakage from the roof, walls, basement or other portion of the Premises or Project, except only, with respect to any Indemnitee, to the extent such injury, death or damage is caused by the sole active negligence or willful misconduct
of such Indemnitee and not covered by the insurance required to be carried by Tenant hereunder or except to the extent such limitation on liability is prohibited by law. The provisions of this Section 8.A shall survive the expiration or earlier
termination of this Lease until all claims within the scope of this Section 8.A are fully, finally, and absolutely barred by the applicable statutes of limitations. 
  
 B. Indemnification. 
  
 1. Tenant shall indemnify, protect, defend (by counsel reasonably satisfactory to Landlord) and hold
harmless Landlord and its officers, directors, employees and agents (each, an “Indemnitee” and collectively, the “Indemnitees”), and each of them, against any and all obligations, losses, claims, actions (including
remedial or enforcement actions of any kind and administrative or judicial proceedings, suits, orders or judgments), causes of action, 

  

 18 








 
liabilities, penalties, damages (including consequential and punitive damages), costs and expenses (including reasonable attorneys’ and
consultants’ fees and expenses) (collectively, “Claims”) arising from any of the following, including, but not limited to, Claims brought by or on behalf of employees of Tenant, with respect to which Tenant waives, for the
benefit of the Indemnitees, any immunity to which Tenant may be entitled under any worker’s compensation laws: (a) any cause in or on the Premises, or (b) any act or omission or negligence of Tenant or any person or entity claiming by or
through Tenant (including any assignee or subtenant), or any of their respective members, partners, employees, contractors, agents, customers, visitors, licensees or other persons in or about the Project by reason of Tenant’s occupancy of the
Premises (each a “Tenant Party” and, collectively, “Tenant Parties”); provided, however, that, with respect to any Indemnitee, Tenant’s obligations under this Section shall be inapplicable to the extent such
Claims arise solely from the active negligence or willful misconduct of such Indemnitee, or to the extent such obligations are prohibited by applicable law. 
  
 2. Tenant’s duty to defend Landlord and the other Indemnitees under this Section 8.B is separate and independent of Tenant’s
duty to indemnify the Indemnitees. The duty to defend includes claims for which the Indemnitees may be liable without fault or strictly liable. The duty to defend applies regardless of whether the issues of negligence, liability, fault, default, or
other obligation on the part of Tenant Parties have been determined. The duty to defend applies immediately, regardless of whether any Indemnitees have paid any sums or incurred any detriment arising out of or relating (directly or indirectly) to
any Claims. The parties expressly intend that Indemnitees shall be entitled to obtain summary adjudication or summary judgment regarding Tenant’s duty to defend the Indemnitees at any stage of any claim or suit within the scope of this Section.

  
 3. Tenant’s obligations under this
Section shall survive the expiration or earlier termination of this Lease until all Claims within the scope of this Section 8.B are fully, finally, and absolutely barred by the applicable statutes of limitations. 
  
 C. Tenant’s Insurance. Tenant shall maintain
insurance as follows, with such other terms, coverages and insurers, as Landlord shall reasonably require from time to time: 
  
 1. Commercial General Liability Insurance, with (a) Contractual Liability including the indemnification provisions contained in this
Lease, (b) a severability of interest endorsement, (c) limits of not less than Two Million Dollars ($2,000,000) combined single limit per occurrence and not less than Four Million Dollars ($4,000,000) in the aggregate for bodily injury, sickness or
death, and property damage. 
  
 2. Property
Insurance against “All Risks” of physical loss covering the replacement cost of all improvements, fixtures and personal property and business interruption. 
  

 19 








 3. Workers’ compensation or similar insurance in form and amounts required by law,
and Employer’s Liability with not less than the following limits: 
  

				
	 Each Accident:
	  	$	500,000
	 Disease—Policy Limit:
	  	$	500,000
	 Disease—Each Employee:
	  	$	500,000

  
 Tenant’s insurance shall be primary and not contributory to that carried by Landlord, its agents, or mortgagee. Landlord, and if any, Landlord’s building manager or agent, mortgagee and ground lessor shall be named as additional
insureds under the insurance required of the Tenant in Section 8.C(1). The company or companies writing any insurance which Tenant is required to maintain under this Lease, as well as the form of such insurance, shall at all times be subject to
Landlord’s approval, and any such company shall be licensed to do business in the state in which the Building is located. Such insurance companies shall have a A.M. Best rating of A VI or better. 
  
 4. Tenant shall cause any contractor of Tenant performing
work on the Premises to maintain insurance as follows, with such other terms, coverages and insurers, as Landlord shall reasonably require from time to time: 
  

(a) Commercial General Liability Insurance, including contractor’s liability coverage, contractual liability coverage, completed
operations coverage, broad form property damage endorsement, and contractor’s protective liability coverage, to afford protection with limits, for each occurrence, of not less than One Million Dollars ($1,000,000) with respect to personal
injury, death or property damage. 
  
 (b)
Workers’ compensation or similar insurance in form and amounts required by law, and Employer’s Liability with not less than the following limits: 
  

				
	 Each Accident:
	  	$	500,000
	 Disease—Policy Limit:
	  	$	500,000
	 Disease—Each Employee:
	  	$	500,000

  
 Such
insurance shall contain a waiver of subrogation provision in favor of Landlord and its agents. Tenant’s contractor’s insurance shall be primary and not contributory to that carried by Tenant, Landlord, their agents or mortgagees. Tenant
and Landlord, and if any, Landlord’s building manager or agent, mortgagee or ground lessor shall be named as additional insured on Tenant’s contractor’s insurance policies. 
  
 D. Insurance Certificates. Tenant shall deliver to
Landlord certificates evidencing all required insurance no later than five (5) days prior to the Commencement Date and each renewal date. Each certificate will provide for thirty (30) days prior written notice of cancellation to Landlord and Tenant.

  
 E. Landlord’s Insurance. Subject
to reimbursement as an Operating Cost in accordance with the provisions of Section 2 hereof, Landlord shall procure and maintain in effect throughout the Term of this Lease commercial general liability insurance, property insurance and/or such other
types of insurance as Landlord reasonably deems necessary or advisable to 

  

 20 








 
carry. Such coverages shall be in such amounts, from such companies and on such other terms and conditions as Landlord may from time to time reasonably
determine, and Landlord shall have the right, but not the obligation, to change, cancel, decrease or increase any insurance coverages in respect of the Building, add additional forms of insurance as Landlord shall deem reasonably necessary, and/or
obtain umbrella or other policies covering both the Building and other assets owned by or associated with Landlord or its affiliates, in which event the cost thereof shall be equitably allocated. 
  
 F. Waiver of Subrogation. Landlord and Tenant hereby
waive and release any and all rights of recovery against the other party, including officers, employees, agents and authorized representatives (whether in contract or tort) of such other party, that arise or result from any and all loss of or damage
to any property of the waiving party located within or constituting part of the Building, including the Premises, to the extent of amounts payable under a standard ISO Commercial Property insurance policy, or such additional property coverage as the
waiving party may carry (with a commercially reasonable deductible), whether or not the party suffering the loss or damage actually carries any insurance, recovers under any insurance or self-insures the loss or damage. Each party shall have their
property insurance policies issued in such form as to waive any right of subrogation as might otherwise exist. This mutual waiver is in addition to any other waiver or release contained in this Lease. 
  
 9. FIRE AND OTHER CASUALTY. 
  
 A. Termination. If a fire or other casualty causes
damage to the Building or the Premises, and sufficient insurance proceeds will be available to Landlord to cover the cost of any restoration to the Building and Premises, Landlord shall engage a registered architect to estimate, within one (1) month
of the casualty, to both Landlord and Tenant the amount of time needed to restore the Building and the Premises to tenantability, using standard working methods without the payment of overtime and other premiums. If the time needed exceeds nine (9)
months from the beginning of the restoration, or two (2) months therefrom if the restoration would begin during the last twenty-four (24) months of the Lease, then in the case of damage to the Premises, either Landlord or Tenant may terminate this
Lease, and in the case of damage to the Building, Landlord may terminate this Lease, by notice to the other party within ten (10) days after the notifying party’s receipt of the architect’s estimate. If sufficient insurance proceeds will
not be available to Landlord to cover the cost of any restoration to the Building or the Premises, Landlord may terminate this Lease by written notice to Tenant. Any termination pursuant to this Section 9.A shall be effective thirty (30) days from
the date of such termination notice and Rent shall be paid by Tenant to that date, with an abatement for any portion of the Premises which has been rendered untenantable as a result of the casualty (except to the extent that the casualty was caused
by the gross negligence or intentional misconduct of Tenant, its agents, employees, contractors, subtenants or assignees and Landlord does not receive insurance proceeds sufficient to cover the rent interruption during such period). 
  
 B. Restoration. If a casualty causes damage to the
Building or the Premises but this Lease is not terminated for any reason, then subject to the rights of any mortgagees or ground lessors, Landlord shall obtain the applicable insurance proceeds and diligently restore the Building and the Premises
subject to current Governmental Requirements. Landlord’s obligation, should it elect or be obligated to repair or rebuild, shall be limited to the basic 

  

 21 








 
Premises as demised and delivered to Tenant on the Commencement Date, building-standard tenant improvements, or the basic Building, as the case may be, and
Tenant shall, at Tenant’s expense, replace or fully repair damaged improvements made pursuant to Section 5 hereof, any tenant improvements in excess of the building standard (except as may have been demised and delivered to Tenant on the
Commencement Date), personal property and fixtures. Rent shall be abated on a per diem basis during the restoration for any portion of the Premises which is untenantable, except to the extent that the casualty was caused by the gross negligence or
intentional misconduct of Tenant, its agents, employees, contractors, subtenants or assignees and Landlord does not receive insurance proceeds sufficient to cover the rent interruption during such period. Tenant shall not be entitled to any
compensation or damages from Landlord for loss of the use of the Premises, damage to Tenant’s personal property and trade fixtures or any inconvenience occasioned by such damage, repair or restoration. Tenant hereby waives the provisions of
Section 1932, Subdivision 2, and Section 1933, Subdivision 4, of the California Civil Code, and the provisions of any similar law hereinafter enacted. 
  
 10. EMINENT DOMAIN. If a part of the Project is taken by eminent domain or deed in lieu thereof which is so substantial that the Premises cannot
reasonably be used by Tenant for the operation of its business, then either party may terminate this Lease effective as of the date of the taking. If any substantial portion of the Project is taken without affecting the Premises, then Landlord may
terminate this Lease as of the date of such taking; provided, however, that Landlord shall exercise its right to terminate this Lease under this sentence only if it terminates the leases of all tenants similarly affected by the taking and with
respect to which Landlord has a comparable termination right. Rent shall abate from the date of the taking in proportion to any part of the Premises taken. The entire award for a taking of any kind shall be paid to Landlord, and Tenant shall have no
right to share in the award. All obligations accrued to the date of the taking shall be performed by the party liable to perform said obligations, as set forth herein. Tenant hereby waives any and all rights it might otherwise have pursuant to
Section 1265.130 of The California Code of Civil Procedure. 
  
 11. RIGHTS RESERVED TO LANDLORD. 
  
 Landlord may exercise at any time any of the following rights respecting the operation of the Project without liability to Tenant of any kind: 
  
 A. Name. To change the name of the Building or the Project, or the street address of the Building or the suite number(s) of the
Premises. 
  
 B. Signs. To install, modify
and/or maintain any signs on the exterior and in the interior of the Building or on the Project, and, subject to Section 6.B above, to approve at its reasonable discretion, prior to installation, any of Tenant’s signs in the Premises visible
from the common areas or the exterior of the Building. 
  
 C. Window Treatments. To approve, at its discretion, prior to installation, any shades, blinds, ventilators or window treatments of any kind, as well as any lighting within the Premises that may be visible from the exterior of the
Building or any interior common area. 
  

 22 








 D. Keys. To retain and use, subject to Section 11.E below, passkeys to enter the
Premises or any door within the Premises. Tenant shall not alter or add any lock or bolt. 
  
 E. Access. To have access to the Premises with twenty-four hours’ prior notice (except in the case of an emergency, in which
case Landlord shall have the right to immediate access) to inspect the Premises, to post notices of non-responsibility in connection with any Work, to make repairs, alterations, additions or improvements to the Premises or Building, and to perform
any other obligations of Landlord hereunder, all without abatement of Rent. 
  
 F. Preparation for Reoccupancy. To decorate, remodel, repair, alter or otherwise prepare the Premises for reoccupancy at any time after Tenant abandons the Premises, without relieving Tenant of any obligation
to pay Rent. 
  
 G. Heavy Articles. To
reasonably approve the weight, size, placement and time and manner of movement within the Building of any safe, central filing system or other heavy article of Tenant’s property. Tenant shall move its property entirely at its own risk.

  
 H. Show Premises. To show the Premises
at any reasonable time to prospective purchasers, brokers, lenders, mortgagees, investors, rating agencies or others and, during the last six (6) months of the Term, as it may be extended, to prospective tenants, provided that Landlord gives
reasonable prior notice to Tenant and does not materially interfere with Tenant’s use of the Premises. 
  
 I. Intentionally omitted. 
  
 J. Use of Lockbox. To designate a lockbox collection agent for collections of amounts due Landlord. In that case, the date of
payment of Rent or other sums shall be the date of the agent’s receipt of such payment or the date of actual collection if payment is made in the form of a negotiable instrument thereafter dishonored upon presentment. However, Landlord may
reject any payment for all purposes as of the date of receipt or actual collection by mailing to Tenant within a reasonable time after such receipt or collection a check equal to the amount sent by Tenant. 
  
 K. Repairs and Alterations. To make repairs or
alterations to the Project and in doing so transport any required material through the Premises, to close entrances, doors, corridors, elevators and other facilities in the Project, to open any ceiling in the Premises, or to temporarily suspend
services or use of common areas in the Building. Landlord may perform any such repairs or alterations during ordinary business hours, except that Tenant may require any work in the Premises to be done after business hours if Tenant pays Landlord for
overtime and any other expenses incurred. Landlord may do or permit any work on any nearby building, land, street, alley or way. 
  
 L. Building Services. To install, use and maintain through the Premises, pipes, conduits, wires and ducts serving the Building,
provided that such installation, use and maintenance does not unreasonably interfere with Tenant’s use of the Premises. 
  

 23 








 M. Use of Roof. To install, operate, maintain and repair any satellite dish,
antennae, equipment, or other facility on the roof of the Building or to use the roof of the Building in any other manner, or to allow any entity selected by Landlord to undertake the foregoing, provided that such installation, operation,
maintenance, repair or use does not unreasonably interfere with Tenant’s use of the Premises. 
  
 N. Other Actions. To take any other action which Landlord deems reasonable in connection with the operation, maintenance or
preservation of the Building and the Project. 
  
 12.
DEFAULTS. 
  
 A. Tenant’s
Default. Any of the following shall constitute a default by Tenant: 
  
 1. Rent Default. Tenant fails to pay any Rent and such failure continues for five (5) days or more following Landlord’s written notice of such failure; 
  
 2. Assignment/Sublease or Hazardous Substances
Default. Tenant defaults (after the expiration of any applicable notice and cure period, or if none is specified, after ten (10) days written notice and opportunity to cure) in its obligations under Section 16 (Subordination), Section 17
(Assignment and Sublease), Section 19 (Estoppel Certificate) or Section 28 (Hazardous Substances); 
  
 3. Other Performance Default. Tenant fails to perform any other obligation to Landlord under this Lease, and such failure continues
for twenty (20) days after written notice from Landlord or Landlord’s agent, except that if Tenant begins to cure its failure within the twenty (20) day period but cannot reasonably complete its cure within such period, then, so long as Tenant
continues to diligently attempt to cure its failure, the twenty (20) day period shall be extended to ninety (90) days, or such lesser period as is reasonably necessary to complete the cure; 
  
 4. Credit Default. One of the following credit
defaults occurs: 
  
 (a) Tenant (or any
guarantor of Tenant’s obligations hereunder) commences any proceeding under any law relating to bankruptcy, insolvency, reorganization or relief of debts, or seeks appointment of a receiver, trustee, custodian or other similar official for the
Tenant (or the guarantor) or for any substantial part of its property, or any such proceeding is commenced against Tenant (or the guarantor) and either remains undismissed for a period of thirty (30) days or results in the entry of an order for
relief against Tenant (or the guarantor) which is not fully stayed within seven (7) days after entry; or 
  
 (b) Any third party obtains a levy or attachment under process of law against Tenant’s leasehold interest. 
  
 5. Vacation or Abandonment Default. Tenant vacates or
abandons the Premises. 
  

 24 








 Tenant acknowledges and agrees that, notwithstanding the foregoing provisions of this
Section 12, any notices required to be given by Landlord under this Section 12 shall, in each case, be in lieu of, and not in addition to, any notice required under Section 1161 of the California Code of Civil Procedure, and shall be deemed to
satisfy the requirement, if any, that notice be given pursuant to such section, provided that the time and content of such notice otherwise satisfy the requirements of law. 
  
 B. Landlord Defaults. Landlord shall be in default hereunder if Landlord has not begun and pursued
with reasonable diligence the cure of any failure of Landlord to meet its obligations hereunder within thirty (30) days after the receipt by Landlord of written notice from Tenant of the alleged failure to perform. Tenant hereby covenants that,
prior to the exercise of any remedies relating to termination or rescission of the Lease, Tenant will give notice and a reasonable time to cure any default by Landlord to any holder of a mortgage or deed of trust encumbering Landlord’s interest
in the Project of which Tenant has been given notice. Notwithstanding anything contained herein to the contrary, Landlord shall not be in default under this Lease to the extent Landlord is unable to perform any of its obligations on account of any
prevention, delay, stoppage due to strikes, lockouts, inclement weather, labor disputes, inability to obtain labor, materials, fuels, energy or reasonable substitutes therefor, governmental restrictions, regulations, controls, actions or inaction,
civil commotion, fire or other acts of god, national emergency, acts of war or terrorism or any other cause of any kind beyond the reasonable control of Landlord (except financial inability). 
  
 13. LANDLORD REMEDIES. UPON A DEFAULT, LANDLORD SHALL HAVE THE
FOLLOWING REMEDIES, IN ADDITION TO ALL OTHER RIGHTS AND REMEDIES PROVIDED BY LAW OR OTHERWISE PROVIDED IN THIS LEASE, TO WHICH LANDLORD MAY RESORT CUMULATIVELY OR IN THE ALTERNATIVE: 
  
 A. Termination of Lease. Landlord may elect by notice to Tenant to terminate this Lease, in which
event, Tenant shall immediately vacate the Premises and deliver possession to Landlord. 
  
 B. Civil Code Section 1951.4 Remedy. Even though Tenant has breached this Lease, this Lease shall continue in effect for so long as
Landlord does not terminate Tenant’s right to possession, and Landlord shall have all of its rights and remedies, including the right, pursuant to California Civil Code Section 1951.4, to recover all rent as it becomes due under this Lease, if
Tenant has the right to sublet or assign, subject only to reasonable limitations. Acts of maintenance or preservation or efforts to relet the Premises or the appointment of a receiver upon initiative of Landlord to protect Landlord’s interest
under this Lease shall not constitute a termination of Tenant’s right to possession unless written notice of termination is given by Landlord to Tenant. 
  

C. Lease Termination Damages. If Landlord elects to terminate this Lease, then this Lease shall terminate on the date for
termination set forth in such notice. Tenant shall immediately vacate the Premises and deliver possession to Landlord, and Landlord may repossess the Premises and may, at Tenant’s sole cost, remove any of Tenant’s signs and any of its
other property, without relinquishing its right to receive Rent or any other right against Tenant. On termination, Landlord has the right to recover from Tenant as damages: 
  
 1. The worth at the time of award of unpaid Rent and other sums due and payable which had been earned at the
time of termination; plus 
  

 25 








 2. The worth at the time of award of the amount by which the unpaid Rent and other sums
due and payable which would have been earned after termination until the time of award exceeds the amount of such Rent loss that Tenant proves could have been reasonably avoided; plus 
  
 3. The worth at the time of award of the amount by which the unpaid Rent and other sums due and payable for
the balance of the Term after the time of award exceeds the amount of such Rent loss that Tenant proves could be reasonably avoided; plus 
  
 4. Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform
Tenant’s obligations under this Lease, or which, in the ordinary course of things, would be likely to result therefrom, including, without limitation, any costs or expenses incurred by Landlord: (i) in retaking possession of the Premises; (ii)
in maintaining, repairing, preserving, restoring, replacing, cleaning, altering or rehabilitating the Premises or any portion thereof, including such acts for reletting to a new tenant or tenants; (iii) for leasing commissions; or (iv) for any other
costs necessary or appropriate to relet the Premises; plus 
  
 5. At Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by the laws of the State of California. 
  
 The “worth at the time of award” of the amounts
referred to in Sections 13.C(1) and 13.C(2) is computed by allowing interest at the Interest Rate on the unpaid rent and other sums due and payable from the termination date through the date of award. The “worth at the time of award” of
the amount referred to in Section 13.C(3) is computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus one percent (1%). Tenant waives redemption or relief from forfeiture under
California Code of Civil Procedure Sections 1174 and 1179, or under any other present or future law, if Tenant is evicted or Landlord takes possession of the Premises by reason of any default of Tenant hereunder. 
  
 D. Landlord’s Remedies Cumulative. All of
Landlord’s remedies under this Lease shall be in addition to all other remedies Landlord may have at law or in equity, including, without limitation, the remedy described in California Civil Code Section 1951.4 (pursuant to which Landlord may
continue this Lease in effect after Tenant’s breach and abandonment and recover rent as it becomes due if Tenant has the right to sublet or assign the Lease, subject to reasonable limitations). Waiver by Landlord of any breach of any obligation
by Tenant shall be effective only if it is in writing, and shall not be deemed a waiver of any other breach, or any subsequent breach of the same obligation. The possession of Tenant’s funds, negotiation of Tenant’s negotiable instruments,
or acceptance of Tenant’s payment by Landlord or its agents shall not constitute a waiver of any breach by Tenant, and if such possession, negotiation or acceptance occurs after Landlord’s notice to Tenant, or termination of this Lease or
of Tenant’s right to possession, such possession, negotiation or acceptance shall not affect such notice or termination. Acceptance of payment by Landlord after commencement of a legal proceeding or 

  

 26 








 
final judgment shall not affect such proceeding or judgment. Landlord may advance such monies and take such other actions for Tenant’s account as
reasonably may be required to cure or mitigate any default by Tenant. Tenant shall immediately reimburse Landlord for any such advance, and such sums shall bear interest at the Interest Rate until paid. 
  
 E. WAIVER OF TRIAL BY JURY. EACH PARTY WAIVES
TRIAL BY JURY IF ANY LEGAL PROCEEDING IS BROUGHT BY THE OTHER IN CONNECTION WITH THIS LEASE. EACH PARTY SHALL BRING ANY ACTION AGAINST THE OTHER IN CONNECTION WITH THIS LEASE IN A FEDERAL OR STATE COURT LOCATED IN SANTA CLARA COUNTY, CALIFORNIA,
CONSENTS TO THE JURISDICTION OF SUCH COURTS, AND WAIVES ANY RIGHT TO HAVE ANY PROCEEDING TRANSFERRED FROM SUCH COURTS ON THE GROUND OF IMPROPER VENUE OR INCONVENIENT FORUM. THE PROVISIONS OF THIS SECTION 13.E SHALL SURVIVE THE EXPIRATION OR EARLIER
TERMINATION OF THIS LEASE. 
  
 14. SURRENDER. Upon the
expiration or earlier termination of this Lease for any reason, Tenant shall surrender the Premises to Landlord in its condition existing as of the date Landlord delivers possession of the Premises to Tenant, normal wear and tear and damage by fire
or other casualty excepted, with all interior walls repaired if marked or damaged, all carpets cleaned, all broken, marred or nonconforming acoustical ceiling tiles replaced, all windows washed, the plumbing and electrical systems and lighting in
good order and repair, including replacement of any burned out or broken light bulbs or ballasts, the HVAC equipment serviced and repaired by a reputable and licensed service firm acceptable to Landlord, and all floors cleaned and waxed, all to the
reasonable satisfaction of Landlord. Tenant shall remove from the Premises and the Project all of Tenant’s trade fixtures, furniture, moveable equipment and other personal property, and any Work which Landlord elects to be removed pursuant to
Section 5.D, and shall restore the Premises to its condition prior to their installation, including, without limitation, repairing all damage caused by the installation or removal of any of the foregoing items. If Tenant does not timely remove such
property, then Tenant shall be conclusively presumed to have, at Landlord’s election: (a) conveyed such property to Landlord without compensation or (b) abandoned such property, and Landlord may dispose of or store any part thereof in any
manner at Tenant’s sole cost, without waiving Landlord’s right to claim from Tenant all expenses arising out of Tenant’s failure to remove the property, and without liability to Tenant or any other person. Landlord shall have no duty
to be a bailee of any such personal property. If Landlord elects to consider such property abandoned, Tenant shall be liable to Landlord for the costs of: (i) removal of any such Work or personal property, (ii) storage, transportation, and
disposition of the same, and (iii) repair and restoration of the Premises, together with interest thereon at the Interest Rate from the date of expenditure by Landlord. In addition, if the Premises are not so surrendered at the termination of this
Lease, Tenant shall indemnify Landlord against all loss or liability, including reasonable attorneys’ fees and costs, resulting from delay by Tenant in so surrendering the Premises. 
  
 15. HOLDOVER. Tenant shall have no right to holdover possession of the Premises after the expiration or termination
of this Lease without Landlord’s prior written consent which Landlord may withhold in its sole and absolute discretion. If, however, Tenant retains possession of any part of the Premises after the Term, Tenant shall become a tenant at
sufferance 

  

 27 








 
only, for the entire Premises upon all of the terms of this Lease as might be applicable to such tenancy, except that Tenant shall pay an amount equal to one
hundred fifty percent (150%) of the Base Rent and Operating Cost Share Rent payable by Tenant immediately prior to such holding over, computed on a monthly basis for each full or partial month Tenant remains in possession. Tenant shall also protect,
defend, indemnify and hold Landlord harmless from and against all Claims resulting from such failure, including, without limiting the generality of the foregoing, any claims made by any succeeding tenant founded upon such failure to surrender and
any lost profits to Landlord resulting therefrom. No acceptance of Rent or other payments by Landlord under these holdover provisions shall operate as a waiver of Landlord’s right to regain possession or any other of Landlord’s remedies.

  
 16. SUBORDINATION TO GROUND LEASES AND MORTGAGES.

  
 A. Subordination. 
  
 1. This Lease shall be subordinate to any present or future
ground lease or mortgage (each a “Superior Interest”) respecting the Project, and any amendments to such ground lease or mortgage, at the election of the ground lessor or mortgagee as the case may be (each a “Security
Holder”), effected by notice to Tenant in the manner provided in this Lease. The subordination shall be effective upon such notice, but at the request of Landlord or such Security Holder, Tenant shall within ten (10) days after the request,
execute and deliver to the requesting party any reasonable documents provided to evidence the subordination. Any mortgagee has the right, at its sole option, to subordinate its mortgage to the terms of this Lease, without notice to, nor the consent
of, Tenant. 
  
 2. With respect to any present or
future ground lease or mortgage to which this Lease is subordinate, Landlord shall, as a condition to such subordination, obtain from the Security Holder, for the benefit of Tenant, a non-disturbance agreement, in commercially reasonable form, that
(a) except to the extent necessary to protect the Security Holder in the event of circumstances in which its security is impaired, will not effect an amendment to this Lease which materially increases Tenant’s obligations or materially
diminishes Tenant’s rights hereunder, and (b) provides generally that as long as Tenant is not in default under this Lease, this Lease will not be terminated if such Security Holder (or any successor or assign thereof, including without
limitation, any purchaser at a foreclosure sale and any transferee pursuant to a deed in lieu of foreclosure, and their successors and assigns) acquires title to the Project by reason of foreclosure proceedings, acceptance of a deed in lieu of
foreclosure, or termination of the leasehold interest of Landlord, provided that Tenant attorns to such Security Holder or other successor owner of the Project in accordance with its reasonable requirements. Tenant will bear all reasonable costs and
expenses (including attorneys’ fees) of the Security Holder of such Superior Interest in connection with obtaining the non-disturbance agreement. 
  
 B. Termination of Ground Lease or Foreclosure of Mortgage. If any ground lease is terminated or mortgage foreclosed or deed in lieu
of foreclosure given and the ground lessor, mortgagee, or purchaser at a foreclosure sale shall thereby become the owner of the Project, Tenant shall attorn to such ground lessor or mortgagee or purchaser without any deduction or setoff by Tenant,
and this Lease shall continue in effect as a direct lease between Tenant and such ground lessor, mortgagee or purchaser. The ground lessor or mortgagee or 

  

 28 








 
purchaser shall be liable as Landlord only during the time such ground lessor or mortgagee or purchaser is the owner of the Project. At the request of
Landlord, ground lessor or mortgagee, Tenant shall execute and deliver within ten (10) days after the request any document furnished by the requesting party to evidence Tenant’s agreement to attorn. 
  
 C. Security Deposit. Any ground lessor or mortgagee
shall be responsible for the return of any security deposit by Tenant only to the extent the security deposit, if any, is received by such ground lessor or mortgagee. 
  
 D. Notice and Right to Cure. Tenant agrees to send by registered or certified mail to any ground
lessor or mortgagee, identified in any notice from Landlord to Tenant, a copy of any notice of default sent by Tenant to Landlord. If Landlord fails to cure such default within the required time period under this Lease, but ground lessor or
mortgagee begins to cure within ten (10) days after such period and proceeds diligently to complete such cure, then ground lessor or mortgagee shall have such additional time as is necessary to complete such cure, including any time necessary to
obtain possession if possession is necessary to cure, and Tenant shall not begin to enforce its remedies relating to termination of this Lease, if any, so long as the cure is being diligently pursued. 
  
 E. Definitions. As used in this Section 16,
“mortgage” shall include “trust deed” and “deed of trust”; “mortgagee” shall include “trustee”, “beneficiary” and the mortgagee of any ground lessee; and “ground lessor”,
“mortgagee”, and “purchaser at a foreclosure sale” shall include, in each case, all of its successors and assigns, however remote. 
  
 17. ASSIGNMENT AND SUBLEASE. 
  
 A. In General. Tenant shall not, without Landlord’s prior written consent, in each case: (i) make or allow any assignment or
transfer, by operation of law or otherwise, of any part of Tenant’s interest in this Lease, (ii) sublet any part of the Premises, or (iii) permit anyone other than Tenant and its employees to occupy any part of the Premises (all of the
foregoing are hereinafter sometimes referred to individually as a “Transfer”, and collectively as “Transfers”, any person to whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a
“Transferee”, and any person by whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a “Transferor”). Tenant shall remain primarily liable for all of its obligations under this
Lease, notwithstanding any Transfer. No consent granted by Landlord shall be deemed to be a consent to any subsequent Transfer. Tenant shall pay all of Landlord’s reasonable attorneys’ fees and reasonable other expenses (not to exceed
$1,500, unless a dispute arises, in which event the provisions of Section 25.Z below shall apply) incurred in connection with any consent requested by Tenant or in considering any proposed Transfer. Any Transfer without Landlord’s prior written
consent shall be void. Unless otherwise specified in this Lease, if Tenant shall assign this Lease or sublet or otherwise Transfer the Premises, or any portion thereof, any rights of Tenant to renew this Lease, to extend the Term or to lease
additional space in the Project shall be extinguished thereby and will not be transferred to the Transferee, all such rights being personal to the Tenant named herein. In addition, Tenant shall not, without Landlord’s prior written consent,
which Landlord may withhold in its sole discretion, mortgage, pledge or encumber this Lease, the term or estate hereby granted or any interest hereunder. 
  

 29 








 B. Landlord’s Consent. Landlord will not unreasonably withhold, delay, or
condition its consent to any proposed Transfer. It shall be reasonable for Landlord to withhold its consent to any Transfer if (i) Tenant is in default under this Lease and the default will not be cured as a condition of the Transfer, (ii) the
proposed Transferee is negotiating with Landlord to lease space in the Project at such time, or has negotiated with Landlord during the sixty (60) day period immediately preceding Tenant’s request for consent, (iii) the financial
responsibility, nature of business, and character of the proposed Transferee are not all reasonably satisfactory to Landlord, (iv) in the reasonable judgment of Landlord the purpose for which the Transferee intends to use the Premises (or a portion
thereof) is not in keeping with Landlord’s standards for the Building or are in violation of the terms of this Lease or any other leases in the Project, or (v) the proposed Transferee is a government entity. The foregoing shall not exclude any
other reasonable basis for Landlord to withhold its consent. 
  
 C. Procedure. Tenant shall notify Landlord of any proposed Transfer at least twenty (20) days prior to its proposed effective date. The notice shall include the name and address of the proposed Transferee, its
corporate affiliates in the case of a corporation and its partners in the case of a partnership, a description of the portion of the Premises that is subject to the Transfer (the “Transfer Premises”), a calculation of the Transfer
Premium (as defined in Section 17.F below) payable in connection with the Transfer, an executed copy of the proposed Transfer agreement, and sufficient information to permit Landlord to determine the financial responsibility and character of the
proposed Transferee (including, without limitation, the most recent financial statements for the proposed Transferee). As a condition to the effectiveness of any assignment of this Lease, the assignee shall execute and deliver to Landlord, at least
fifteen (15) days prior to the effective date of the assignment, Landlord’s standard form of Consent to Assignment, providing for, among other things, an assumption of all of the obligations of Tenant under this Lease. As a condition to the
effectiveness of any other Transfer, Transferee shall execute and deliver to Landlord, at least fifteen (15) days prior to the effective date of such Transfer, Landlord’s standard consent form, providing, among other things, (1) an assumption
of all of the obligations of Tenant under this Lease to the extent applicable to the Transfer Premises (excluding the payment of Rent), (2) the Transferee’s obligation to indemnify Landlord and the other Indemnitees consistent with
Tenant’s indemnification obligations in Section 8.B above, and (3) the Transferee’s agreement that any such Transfer shall be subordinate and subject to the provisions of this Lease, and if this Lease shall be terminated during the term of
any such Transfer, Landlord shall have the right to: (a) treat such Transfer as cancelled and repossess the Transfer Premises by any lawful means, or (b) require that the Transferee attorn to and recognize Landlord as its landlord under any such
Transfer. If Tenant shall default and fail to cure within the time permitted for cure under Section 12 above, Landlord is hereby irrevocably authorized, as Tenant’s agent and attorney-in-fact, to direct any Transferee to make all payments under
or in connection with the Transfer directly to Landlord (which Landlord shall apply towards Tenant’s obligations under this Lease) until such default is cured. 
  
 D. Change of Management or Ownership. Any transfer of the direct or indirect power to affect the
management or policies of Tenant or direct or indirect change in 50% or more of the ownership interest in Tenant shall constitute an assignment of this Lease. 
  

E. Permitted Transfers. If Tenant is not then in default of this Lease, Tenant may assign this Lease or sublet any portion of
the Premises (hereinafter collectively referred to 

  

 30 








 
as a “Permitted Transfer”) to (i) a parent or subsidiary of Tenant, or an entity under common control with Tenant, (ii) any successor entity
to Tenant by way of merger, consolidation or other non-bankruptcy corporate reorganization, or (iii) an entity which acquires all or substantially all of Tenant’s assets (collectively, “Permitted Transferees”, and,
individually, a “Permitted Transferee”); provided that (1) at least ten (10) business days prior to the Transfer, Tenant notifies Landlord of such Transfer, and supplies Landlord with any documents or information reasonably
requested by Landlord regarding such Transfer or Permitted Transferee, including, but not limited to, copies of the sublease or instrument of assignment and copies of documents establishing to the reasonable satisfaction of Landlord that the
transaction in question is one permitted under this Section 17.E, (2) at least ten (10) business days prior to the Transfer, Tenant furnishes Landlord with a written document executed by the proposed Permitted Transferee in which such entity assumes
all of Tenant’s obligations under this Lease with respect to the Transfer Premises, (3) in the case of a Transfer pursuant to clause (ii) above, the successor entity must have a tangible net worth at the time of the Transfer (i.e., not
including intangible assets in the calculation, such as goodwill, patents, copyrights, and trademarks) computed in accordance with generally accepted accounting principles (“Net Worth”) that is at least equal to the Net Worth of
Tenant immediately prior to such Transfer, and (4) any such proposed Transfer is made for a good faith operating business purpose and not, whether in a single transaction or in a series of transactions, be entered into as a subterfuge to evade the
obligations and restrictions relating to Transfers set forth in this Section 17. 
  
 F. Transfer Premium. 
  
 1. If Landlord consents to a Transfer, as a condition thereto which the parties hereby agree is reasonable, Landlord shall be entitled to
receive, as Additional Rent hereunder, fifty percent (50%) of any Transfer Premium derived from such Transfer. As used herein, the term “Transfer Premium” means (a) (i) in the case of an assignment, any consideration (including,
without limitation, payment for leasehold improvements) paid by the assignee on account of such assignment, and (ii) in the case of any other Transfer, all rent, additional rent or other consideration paid by the Transferee to the Transferor
pursuant to such Transfer in excess of the base rent and additional rent payable by such Transferor during the term of the Transfer on a per rentable square foot basis, in either case minus (b) the cost of any leasehold improvements or improvements
allowance incurred or granted by Tenant in connection with the Transfer, up to a maximum of Five Dollars ($5.00) per rentable square foot, any brokerage commissions (not to exceed commissions typically paid in the market at the time of such
subletting or assignment) and reasonable attorneys’ fees paid by Transferor in connection with the Transfer (“Recoverable Expenses”), unless the deduction of such Recoverable Expenses is waived by Transferor pursuant to Section
17.F(2) below. For purposes of calculating the Transfer Premium in connection with a sublease, Recoverable Expenses shall be deducted on an amortized basis, without interest, over the term of the sublease. Payment of the portion of the Transfer
Premium due Landlord hereunder shall be a joint and several obligation of Tenant and the Transferee, and shall be made to Landlord as follows: (x) in the case of an assignment, the Transferor shall pay the portion of the Transfer Premium due to
Landlord within ten (10) days after the Transferor receives the consideration described in clause (a)(i) above; and (y) in the case of any other Transfer, on the first day of each month during the term of the Transfer, the Transferee shall pay
directly to Landlord fifty percent (50%) of the amount by which the rent, additional rent or other consideration due from the Transferee for such month exceeds (1) the 

  

 31 








 
base rent and additional rent payable by the applicable Transferor for said month which is allocable to the Transfer Premises, plus (2) the amortized amount
of Recoverable Expenses allocated to such month, unless such Recoverable Expenses are waived by Transferor pursuant to Section 17.F(2). 
  
 2. Within ninety (90) days after the effective date of any Transfer, Transferor shall provide Landlord a written statement, together with
reasonably detailed invoices therefor, certifying the total amount of Recoverable Expenses in connection with any Transfer and Tenant’s calculation of the Transfer Premium. If Transferor fails to provide such statement and invoices to Landlord
within the ninety (90) day period, Transferor shall be deemed to have waived the deduction of Recoverable Expenses in determining the Transfer Premium. Landlord or its authorized representatives shall have the right at all reasonable times to audit
the books, records and papers of Tenant, and any other Transferor, relating to a Transfer, and shall have the right to make copies thereof. If the Transfer Premium respecting any Transfer shall be found to be understated, Tenant shall within ten
(10) days after demand pay the deficiency, and, if understated by more than five percent (5%), Tenant shall pay Landlord’s costs of such audit. 
  
 G. Recapture. In the case of a proposed assignment, sublease or other Transfer of more than fifty percent (50%) of the rentable
square feet of the Premises which will be effective at any time during the final twelve (12) months of the Term (except a Permitted Transfer pursuant to Section 17.E above), Landlord may terminate this Lease as to the Transfer Premises by giving
Tenant written notice (the “Recapture Notice”) within thirty (30) days after Landlord’s receipt of the proposed fully executed Transfer agreement submitted by Tenant for Landlord’s consent. Such termination shall be
effective as of the termination date set forth in Landlord’s Recapture Notice, and all obligations of Landlord and Tenant under this Lease as to such terminated space shall expire as of such termination date, except those that expressly survive
any termination of this Lease. In the event of a recapture by Landlord, if this Lease shall be canceled with respect to less than the entire Premises, the Rent reserved herein shall be prorated on the basis of the number of rentable square feet
retained by Tenant in proportion to the number of rentable square feet contained in the Premises, and this Lease as so amended shall continue thereafter in full force and effect, and upon request of either party, the parties shall execute written
confirmation of the same. 
  
 H. Tenant
Remedies. Notwithstanding anything to the contrary in this Lease, if Tenant claims that Landlord has unreasonably withheld or delayed its consent under this Section 17 or otherwise has breached or acted unreasonably under this Section 17,
Tenant’s sole remedy shall be declaratory judgment and an injunction for the relief sought or monetary damages. Tenant hereby waives all other remedies, including, without limitation, any right provided under California Civil Code Section
1995.310 or other applicable laws to terminate this Lease. 
  
 18.
CONVEYANCE BY LANDLORD. If Landlord shall at any time transfer its interest in the Project or this Lease, Landlord shall be released of any obligations occurring after such transfer, except the obligation to return to Tenant any security
deposit not delivered to its transferee, and Tenant shall look solely to Landlord’s successors for performance of such obligations. This Lease shall not be affected by any such transfer. 
  

 32 








 19. ESTOPPEL CERTIFICATE. Each party shall, within ten (10) days after receiving a request from
the other party, execute, acknowledge in recordable form, and deliver to the other party or its designee a certificate stating, subject to a specific statement of any applicable exceptions, that this Lease as amended to date is in full force and
effect, that Tenant is paying Rent and other charges on a current basis, and that to the best of the knowledge of the certifying party, the other party has committed no uncured defaults and has no offsets or claims. The certifying party may also be
required to state the date of commencement of payment of Rent, the Commencement Date, the Termination Date, the Base Rent, the current Operating Cost Share Rent estimates, the status of any improvements required to be completed by Landlord, the
amount of any security deposit, and such other matters as may be reasonably requested. If Tenant fails to deliver a certificate within the ten (10) day period set forth above, and such failure continues for an additional three (3) days after
Landlord’s delivery of a notice of such failure to Tenant, then Tenant’s failure shall constitute an acknowledgment by Tenant that the statements included in the estoppel certificate are true and correct, without exception. Tenant’s
failure to execute or deliver an estoppel certificate or other document or instrument required under this Section 19 in a timely manner shall be a material breach of this Lease. 
  
 20. LEASE DEPOSIT. 
  
 A. Tenant shall deposit with Landlord (1) on the date Tenant executes and delivers this Lease, the cash sum set forth in the Schedule for
Prepaid Rent, and (2) on the Commencement Date, the cash sum set forth in the Schedule for Security Deposit (collectively, the “Lease Deposit”). The Prepaid Rent shall be applied by Landlord against Base Rent for the first full
calendar month following the Rent Commencement Date. The Security Deposit shall be held by Landlord as security for the faithful performance by Tenant of all its obligations under this Lease. Tenant agrees that, if Tenant fails to pay any Rent, or
otherwise defaults with respect to any provision of this Lease, Landlord may (but shall not be obligated to), and without prejudice to any other remedy available to Landlord, use, apply or retain all or any portion of the Security Deposit for the
payment of any Rent in default or for the payment of any other sum to which Landlord may become obligated by reason of Tenant’s default, or to compensate Landlord for any loss or damage which Landlord may suffer thereby, including, without
limitation, prospective damages and damages recoverable pursuant to California Civil Code Section 1951.2. Tenant waives the provisions of California Civil Code Section 1950.7, and all other provisions of law now in force or that become in force
after the date of execution of this Lease, that restrict the use or application of the Security Deposit by Landlord. If Landlord uses or applies all or any portion of the Security Deposit as provided above, Tenant shall, within three (3) days after
demand therefor, deposit cash with Landlord in an amount sufficient to restore the Security Deposit to the full amount thereof, and Tenant’s failure to do so shall, at Landlord’s option, be a default under this Lease with no opportunity to
cure. If Tenant performs all of Tenant’s obligations hereunder, the Security Deposit, or so much thereof as has not theretofore been applied by Landlord, shall be returned to Tenant (or, at Landlord’s option, to the last assignee, if any,
of Tenant’s interest hereunder) within thirty (30) days following the expiration of the Term and after Tenant has vacated the Premises; provided, however, that if this Lease is terminated by Landlord pursuant to Section 13 above, or by Tenant
in a bankruptcy proceeding pursuant to 11 U.S.C. §365, Landlord may retain the Security Deposit and apply the same against its damages recoverable pursuant to California Civil Code Section 1951.2. Landlord shall not be deemed to hold the
Security Deposit in trust nor be required to keep the Security Deposit 

  

 33 








 
separate from its general funds, and Tenant shall not be entitled to any interest on the Security Deposit. The Security Deposit shall not be construed as an
advance payment of Rent nor liquidated damages, and if Landlord’s claims hereunder exceed the Security Deposit, Tenant shall remain liable for the balance of such claims. 
  
 B. If Landlord transfers its interest in the Project or this Lease, Landlord may transfer the Security
Deposit to its transferee. Upon such transfer, Landlord shall have no further obligation to return the Security Deposit to Tenant, and Tenant’s right to the return of the Security Deposit shall apply solely against Landlord’s transferee.

  
 21. TENANT’S PERSONAL PROPERTY AND FIXTURES.
Intentionally omitted. 
  
 22. NOTICES. All notices,
consents, approvals and similar communications to be given by one party to the other under this Lease, shall be given in writing, mailed or personally delivered as follows: 
  
 A. Landlord. To Landlord as follows: 
  
 CarrAmerica Realty Corporation 
 1810 Gateway Drive, Suite 150 
 San Mateo, CA 94404 
 Attn: Market Officer 
  
 with a copy to: 
  
 CarrAmerica Realty Corporation 
 1850 K Street, N.W., Suite 500 
 Washington, DC 20006 
 Attn: Lease Administration 
  
 or to such other person at such other address as Landlord may designate by
notice to Tenant. 
  
 B. Tenant. To Tenant
as follows: 
  
 Intervideo, Inc. 
 46430 Fremont Boulevard 
 Fremont, CA 94538 
 Attn:
                     
  
 or to such other person at such other address as Tenant may designate by notice to Landlord. 
  
 Mailed notices shall be sent by United States certified or registered mail, or by a reputable national overnight courier
service, postage prepaid. Mailed notices shall be deemed to have been given on the earlier of actual delivery or three (3) business days after posting in the United States mail in the case of registered or certified mail, and one (1) business day in
the case of overnight courier. 
  

 34 








 23. QUIET POSSESSION. So long as Tenant shall perform all of its obligations under this Lease,
Tenant shall enjoy peaceful and quiet possession of the Premises against any party claiming through the Landlord, subject to all of the terms of this Lease. 
  
 24. REAL ESTATE BROKERS. Tenant represents to Landlord that Tenant has not dealt with any real estate broker with respect to this Lease except for
any broker(s) listed in the Schedule, and no other broker is in any way entitled to any broker’s fee or other payment in connection with this Lease. Tenant shall indemnify and defend Landlord against any Claims by any other broker or third
party for any payment of any kind in connection with this Lease. 
  
 25. MISCELLANEOUS. 
  
 A.
Successors and Assigns. Subject to the limits on Tenant’s assignment contained in Section 17, the provisions of this Lease shall be binding upon and inure to the benefit of all successors and assigns of Landlord and Tenant. 

 
 B. Date Payments Are Due. Except for payments to
be made by Tenant under this Lease which are due upon demand or are due in advance (such as Base Rent), Tenant shall pay to Landlord any amount for which Landlord renders a statement of account within ten (10) days after Tenant’s receipt of
Landlord’s statement. 
  
 C. Meaning of
“Landlord”, “Re-Entry”, “including” and “Affiliate”. The term “Landlord” means only the owner of the Project and the lessor’s interest in this Lease from time to time. The words
“re-entry” and “re-enter” are not restricted to their technical legal meaning. The words “including” and similar words shall mean “without limitation.” The word “affiliate” shall mean a person or
entity controlling, controlled by or under common control with the applicable entity. “Control” shall mean the power directly or indirectly, by contract or otherwise, to direct the management and policies of the applicable entity.

  
 D. Time of the Essence. Time is of the
essence of each provision of this Lease. 
  
 E.
No Option. The submission of this Lease to Tenant for review or execution does not create an option or constitute an offer to Tenant to lease the Premises on the terms and conditions contained herein, and this Lease shall not become effective
unless and until it has been executed and delivered by both Landlord and Tenant. 
  
 F. Severability. If any provision of this Lease is determined to be invalid, illegal or unenforceable, then such provision will be
enforced to the maximum extent possible and the other provisions will remain fully effective and enforceable. 
  
 G. Governing Law. This Lease shall be governed in all respects by the laws of the state in which the Project is located, without
regard to the principles of conflicts of laws. 
  
 H. Lease Modification. Tenant agrees to modify this Lease in any way requested by a mortgagee which does not cause increased expense to Tenant or otherwise adversely affect Tenant’s interests under this Lease. 
  

 35 








 I. No Oral Modification. No modification of this Lease shall be effective unless
it is a written modification signed by both parties. 
  
 J. Landlord’s Right to Cure. Landlord may cure any default by Tenant; any expenses incurred shall constitute Additional Rent due from Tenant on demand by Landlord. 
  
 K. Captions. The captions used in this Lease shall have no effect on the construction of this Lease.

  
 L. Authority. Landlord and Tenant each
represents to the other that it has full power and authority to execute and perform this Lease. 
  
 M. Landlord’s Enforcement of Remedies. Landlord may enforce any of its remedies under this Lease either in its own name or
through an agent. 
  
 N. Entire Agreement.
This Lease, together with all Exhibits, constitutes the entire agreement between the parties. No representations or agreements of any kind have been made by either party which are not contained in this Lease. 
  
 O. Landlord’s Title. Landlord’s title shall
always be paramount to the interest of Tenant, and nothing in this Lease shall empower Tenant to do anything which might in any way impair Landlord’s title. 
  
 P. Light and Air Rights. Landlord does not grant in this Lease any rights to light and air in
connection with Project. Landlord reserves to itself, the Project, the Building below the improved floor of each floor of the Premises, the Building above the ceiling of each floor of the Premises, the exterior of the Premises and the areas on the
same floor outside the Premises, along with the areas within the Premises required for the installation and repair of utility lines and other items required to serve other tenants of the Building. 
  
 Q. Singular and Plural. Wherever appropriate in this
Lease, a singular term shall be construed to mean the plural where necessary, and a plural term the singular. For example, if at any time two parties shall constitute Landlord or Tenant, then the relevant term shall refer to both parties together.

  
 R. No Recording by Tenant. Tenant
shall not record in any public records any memorandum or any portion of this Lease. 
  
 S. Exclusivity. Landlord does not grant to Tenant in this Lease any exclusive right except the right to occupy its Premises.

  
 T. No Construction Against Drafting
Party. The rule of construction that ambiguities are resolved against the drafting party shall not apply to this Lease. 
  
 U. Survival. The waivers of claims or rights, the releases and the obligations of Tenant under this Lease to indemnify, protect,
defend and hold harmless Landlord and other Indemnitees shall survive the expiration or earlier termination of this Lease, and so shall all other 

  

 36 








 
obligations or agreements of Landlord or Tenant hereunder which by their terms survive the expiration or earlier termination of this Lease. 
  
 V. Rent Not Based on Income. No Rent or other payment
in respect of the Premises shall be based in any way upon net income or profits from the Premises. Tenant may not enter into or permit any sublease or license or other agreement in connection with the Premises which provides for a rental or other
payment based on net income or profit. 
  
 W.
Building Manager and Service Providers. Landlord may perform any of its obligations under this Lease through its employees or third parties hired by the Landlord. 
  
 X. Late Charge and Interest on Late Payments. Without limiting the provisions of Section 12.A, if
Tenant fails to pay any installment of Rent or other charge to be paid by Tenant pursuant to this Lease within five (5) business days after the same becomes due and payable, then Tenant shall pay a late charge equal to five percent (5%) of the
amount of such payment. In addition, interest shall be paid by Tenant to Landlord on any late payments of Rent from the date due until paid at the rate provided in Section 2.D(2). Such late charge and interest shall constitute Additional Rent due
and payable by Tenant to Landlord upon the date of payment of the delinquent payment referenced above. Notwithstanding the provisions of this Section 25.X to the contrary, no late charge shall be assessed the first time during the Lease Term that
Rent is not paid within five (5) business days after the date on which it is due and payable, so long as Tenant shall pay any such delinquent amount within three (3) days after notice of such delinquency from Landlord. 
  
 Y. Tenant’s Financial Statements. Within ten
(10) days after Landlord’s written request therefor (which may be made only in connection with a default by Tenant or a bona fide sale, financing or other similar transaction involving the Project), Tenant shall deliver to Landlord the current
certified or, if available, audited annual and quarterly financial statements of Tenant, and annual certified or, if available, audited financial statements of the two (2) years prior to the current year’s financial statements, each with an
opinion of a certified public accountant or Tenant’s chief financial officer, including a balance sheet and profit and loss statement for the most recent prior year, all prepared in accordance with generally accepted accounting principles
consistently applied; provided, however, that as long as Tenant’s financial statements are readily available over the Internet or otherwise publicly available, Tenant shall not be obligated to deliver them to Landlord hereunder, and further
provided that if such statements are not publicly available, Landlord will enter into a reasonable confidentiality agreement relating thereto. 
  
 Z. Attorneys’ Fees. In any arbitration, quasi-judicial or administrative proceedings or any action in any court of competent
jurisdiction, brought by either party to enforce any covenant or any of such party’s rights or remedies under this Lease, including any action for declaratory relief, or any action to collect any payments required under this Lease or to quiet
title against the other party, the prevailing party shall be entitled to reasonable attorneys’ fees and all reasonable costs, expenses and disbursements in connection with such action, including the costs of reasonable investigation,
preparation and professional or expert consultation, which sums may be included in any judgment or decree entered in such action in favor of the prevailing party. In addition, Tenant shall pay reasonable attorneys’ fees and other 

  

 37 








 
costs Landlord incurs in enforcing this Lease in connection with Tenant’s monetary default where an action or proceeding is not brought. 
  
 AA. Other Improvements. If portions of the Project or
property adjacent to the Project (collectively, the “Other Improvements”) are owned by an entity other than Landlord, Landlord, at its option, may enter into an agreement with the owner or owners of any of the Other Improvements to
provide (i) for reciprocal rights of access, use and/or enjoyment of the Project and the Other Improvements, (ii) for the common management, operation, maintenance, improvement and/or repair of all or any portion of the Project and all or any
portion of the Other Improvements, (iii) for the allocation of a portion of Operating Costs, Utility Costs or Capital Costs to the Other Improvements and the allocation of a portion of the operating expenses and taxes for the Other Improvements to
the Project, (iv) for the use or improvement of the Other Improvements and/or the Project in connection with the improvement, construction, and/or excavation of the Other Improvements and/or the Project, and (v) for any other matter which Landlord
deems appropriate or necessary. Nothing contained herein shall be deemed or construed to limit or otherwise affect Landlord’s right to sell all or any portion of the Project or any other of Landlord’s rights described in this Lease.

  
 BB. Consent. Whenever a party has the
right to give or withhold its consent hereunder, unless it is specifically stated that consent is in the party’s sole discretion, said party shall not unreasonably withhold, delay, or condition its consent; provided, however, that the foregoing
shall not apply to matters requiring Landlord’s consent that could have an adverse effect on the structural integrity of the Building or the Building Systems, or affect the exterior of the Building, whereupon in each such case Landlord’s
duty is to act in good faith. 
  
 26. UNRELATED BUSINESS
INCOME. If Landlord is advised by its counsel at any time that any part of the payments by Tenant to Landlord under this Lease may be characterized as unrelated business income under the United States Internal Revenue Code and its regulations,
then Tenant shall enter into any amendment proposed by Landlord to avoid such income, so long as the amendment does not require Tenant to make more payments or accept fewer services from Landlord, than this Lease provides, or materially increase
Tenant’s obligations, or otherwise materially impair Tenant’s rights under this Lease. 
  
 27. BUILDING RENOVATIONS. It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no
obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord
to Tenant except as specifically set forth herein or in the Tenant Improvement Agreement. However, Tenant hereby acknowledges that Landlord may during the Lease Term renovate, improve, alter, or modify (collectively, the
“Renovations”) the Project and/or the Building including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation,
(i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with Governmental Requirements, including regulations relating to the physically disabled, seismic conditions, and
building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among 

  

 38 








 
other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of
the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Landlord shall use commercially reasonable efforts to minimize any interference with the conduct of Tenant’s business during
the Renovations, and no such Renovations shall be designed, constructed, or built in a manner which would materially interfere with Tenant’s business use of the Premises after construction. Tenant hereby agrees that such Renovations and
Landlord’s actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Except as otherwise provided in this Section, Landlord shall have no responsibility
or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant’s business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the
whole or any part of the Premises or of Tenant’s personal property or improvements resulting from the Renovations or Landlord’s actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such
Renovations or Landlord’s actions. 
  
 28. HAZARDOUS
SUBSTANCES. 
  
 A. Prohibition Against
Hazardous Substances. Tenant shall not cause or permit any Hazardous Substances to be brought upon, produced, stored, used, discharged or disposed of in or near the Project without Landlord’s prior written consent, which Landlord may give
or withhold in its reasonable discretion. Any use, handling, storage, treatment, transport, discharge or disposal of any Hazardous Substances in or about the Project by Tenant, its agents, employees, contractors or invitees shall strictly comply
with all applicable Governmental Requirements. Tenant shall be solely responsible for obtaining and complying with all permits necessary for the maintenance and operation of its business, including, without limitation, all permits governing the use,
handling, storage, treatment, transport, discharge and disposal of Hazardous Substances. Tenant shall indemnify, defend and hold Landlord harmless from and against any Claims (including, without limitation, diminution in value of the Premises or the
Project, damages for the loss or restriction on use of leasable space or of any amenity of the Premises or the Project, damages arising from any adverse impact on marketing of space in the Project, Remedial Work, and sums paid in settlement of
claims) which result from or arise out of the use, handling, storage, treatment, transport, release, discharge or disposal of any Hazardous Substances on or about the Project by Tenant or any Tenant Parties; provided, however, that Tenant shall have
no obligation to indemnify, defend and hold Landlord harmless from and against any Claims arising out of Hazardous Substances (1) present in the Premises or the Project prior to Tenant’s occupancy of the Premises or (2) placed on or about the
Premises or the Project by any persons except Tenant or Tenant Parties, except to the extent that Tenant’s activities exacerbate any such Hazardous Substances condition. If, as a result of any use, handling, storage, treatment, transport,
release, discharge or disposal of any Hazardous Substances in or about the Project by Tenant or any Tenant Parties, any lender or governmental agency shall require testing for Hazardous Substances in the Premises, Tenant shall pay for such testing.
Tenant’s obligations under this Section shall survive the expiration or earlier termination of this Lease until all Claims within the scope of this Section 28.A are fully, finally, and absolutely barred by the applicable statutes of
limitations. 
  

 39 








 B. Landlord Notification. Tenant shall promptly provide Landlord with complete
copies of all documents, correspondence and other written materials directed to or from, or relating to, Tenant concerning environmental issues at the Premises or the Project, including, without limitation, documents relating to the release,
potential release, investigation, compliance, cleanup and abatement of Hazardous Substances, and any claims, causes of action or other legal documents related to same. Within twenty-four (24) hours of any unauthorized release, spill or discharge of
Hazardous Substances by Tenant or any Tenant Parties in, on, or about the Premises or Project, Tenant shall provide written notice to Landlord fully describing the event. Tenant shall also provide Landlord with a copy of any document or
correspondence submitted by or on behalf of Tenant to any regulatory agency as a result of or in connection with the unauthorized release, spill or discharge. Within twenty-four (24) hours of receipt by Tenant of any warning, notice of violation,
permit suspension or similar disciplinary measure relating to Tenant’s actual or alleged failure to comply with any environmental law, rule, regulation, ordinance or permit relating to the Premises, Tenant shall provide written notice to
Landlord. 
  
 C. Remedial Work. If any
investigation or monitoring of site conditions or any clean-up, containment, restoration, removal or remediation of Hazardous Substances (collectively, “Remedial Work”) is required under any Governmental Requirements as a result of
any use, handling, storage, treatment, transport, release, discharge or disposal of any Hazardous Substances in or about the Project by Tenant or any Tenant Parties, then Tenant shall perform or cause to be performed the Remedial Work in compliance
with Governmental Requirements or, at Landlord’s option, Landlord may cause such Remedial Work to be performed and Tenant shall reimburse Landlord for the reasonable costs thereof within thirty (30) days after demand therefor. All Remedial Work
performed by Tenant shall be performed by one or more contractors, selected by Tenant and approved in advance in writing by Landlord, and under the supervision of a consulting engineer selected by Tenant and approved in advance in writing by
Landlord. All costs and expenses of such Remedial Work shall be paid by Tenant, including, without limitation, the charges of such contractor(s), the consulting engineer and Landlord’s reasonable attorneys’ and experts’ fees and costs
incurred in connection with monitoring or review of such Remedial Work. 
  
 D. Environmental Questionnaire. Prior to execution of this Lease, Tenant shall complete, execute and deliver to Landlord an Environmental Questionnaire and Disclosure Statement. The completed Environmental
Questionnaire shall be deemed incorporated into this Lease for all purposes, and Landlord shall be entitled to rely fully on the information contained therein. Tenant shall immediately update and resubmit to Landlord the Environmental Questionnaire
if changes occur in the nature, content, handling, storage, use, treatment, transport, discharge, or disposal of the Hazardous Substances described therein. Attached hereto as Exhibit E is a form of Environmental Questionnaire to be executed
in accordance with the foregoing provision. 
  
 E. Definition of “Hazardous Substances”. “Hazardous Substances” means any hazardous or toxic substances, materials or waste which are or become regulated by any local government authority, the state in
which the Project is located or the United States government, including those substances described in the Comprehensive Environmental Response, Compensation and Liability Act of 1980, as amended, 42 U.S.C. Section 9601 et seq., 

  

 40 








 
the Resource Conservation and Recovery Act, as amended, 42 U.S.C. Section 6901 etseq., any other applicable federal, state or local law, and
the regulations adopted under these laws. 
  
 29.
EXCULPATION. Landlord shall have no personal liability under this Lease; its liability shall be limited solely and exclusively to Landlord’s interest in the Project. In no event shall Landlord’s liability extend to any other
property or assets of Landlord, nor shall any officer, director, employee, agent, shareholder, partner, member or beneficiary of Landlord be personally liable for any of Landlord’s obligations hereunder. Further, in no event shall Landlord be
liable under any circumstances for any consequential damages or for injury or damage to, or interference with, Tenant’s business, including but not limited to, loss of profits, loss of rents or other revenues, loss of business opportunity, loss
of goodwill, or loss of use, however occurring. 
  
 30.
COMMUNICATIONS AND COMPUTER LINES. Tenant may install, maintain, replace, remove or use any communications or computer wires and cables (collectively, the “Lines”) at the Project in or serving the Premises, provided that (i)
Tenant shall obtain Landlord’s prior written consent, use an experienced and qualified contractor approved in writing by Landlord, and comply with all of the other provisions of this Lease, (ii) an acceptable number of spare Lines and space for
additional Lines shall be maintained for existing and future occupants of the Project, as determined in Landlord’s reasonable opinion, (iii) the Lines therefor (including riser cables) shall be appropriately insulated to prevent excessive
electromagnetic fields or radiation, and shall be surrounded by a protective conduit reasonably acceptable to Landlord, (iv) any new or existing Lines servicing the Premises shall comply with all Governmental Requirements, (v) as a condition to
permitting the installation of new Lines, Landlord may require that Tenant remove existing Lines located in or serving the Premises and repair any damage in connection with such removal, and (vi) Tenant shall pay all costs in connection with the
foregoing. Landlord reserves the right to require that Tenant remove any Lines located in or serving the Premises which are installed in violation of these provisions, or which are at any time in violation of any Governmental Requirements or
represent a dangerous or potentially dangerous condition. 
  
 31. OPTION TO EXTEND. 
  
 A.
Subject to the terms and conditions set forth below, Tenant may at its option (“Renewal Option”) extend the Term of this Lease for one (1) additional five (5) year period (the “Renewal Term”). If Tenant exercises
the Renewal Option hereunder, all of the terms, covenants and conditions of this Lease shall continue in full force and effect during the Renewal Term, including provisions regarding payment of Additional Rent, which shall remain payable on the
terms herein set forth, except that (i) the Base Rent payable by Tenant during the Renewal Term shall be as determined in accordance with Sections 31.C and 31.D below, (ii) Tenant shall continue to possess and occupy the Premises in their existing
condition, “as is” as of the commencement of the Renewal Term, and Landlord shall have no obligation to repair, remodel, improve or alter the Premises, to perform any other construction or other work of improvement upon the Premises, or to
provide Tenant with any construction or refurbishing allowance whatsoever, and (iii) Tenant shall have no further rights to extend the Term of this Lease after the expiration of the Renewal Term. 
  

 41 








 B. To exercise the Renewal Option, Tenant must deliver an unconditional binding notice to
Landlord via certified mail or hand delivery not sooner than three hundred sixty-five (365) days nor later than one hundred eighty (180) days prior to the expiration of the initial Term of this Lease. Thereafter, the Market Rate for the Renewal Term
shall be determined pursuant to Section 31.C below. Such determination shall be final and shall not be recalculated at the actual commencement of such Renewal Term. If Tenant fails to timely give its notice of exercise, Tenant will be deemed to have
waived its Renewal Option. 
  
 C. The Base Rent
payable by Tenant for the Premises during the Renewal Term shall be ninety-five percent (95%) of the Market Rate (as defined below) for the Premises, valued as of the commencement of the Renewal Term, determined in the manner hereinafter provided;
provided, however, that in no event shall the annual Base Rent payable by Tenant for any year of the Renewal Term be less than the annual Base Rent payable during the last year of the initial Term (“Base Rent Floor”). As used
herein, the term “Market Rate” shall mean the annual amount of Base Rent that a willing tenant would pay, and that a willing landlord would accept, at arm’s length, for space comparable to the Premises within the Project or
other comparable first class office projects in the vicinity of the Project (the “Comparison Projects”), based upon binding lease transactions for tenants in the Comparison Projects that, where possible, commence or are to commence
within six (6) months prior to or within six (6) months after the commencement of the Renewal Term (“Comparison Leases”). Comparison Leases shall include renewal and new non-renewal tenancies, but shall exclude subleases and leases
of space subject to another tenant’s expansion rights. Rental rates payable under Comparison Leases shall be adjusted to account for variations between this Lease and the Comparison Leases with respect to: (i) the length of the Renewal Term
compared to the lease term of the Comparison Leases; (ii) rental structure, including, without limitation, rental rates per rentable square foot (including type, gross or net, and if gross, adjusting for base year or expense stop), additional
rental, escalation provisions, all other payments and escalations; (iii) the size of the Premises compared to the size of the premises of the Comparison Leases; (iv) location, floor levels and efficiencies of the floor(s) for which the determination
is being made; (v) free rent, moving expenses and other cash payments, allowances or other monetary concessions affecting the rental rate; (vi) the age and quality of construction of the Building (including compliance with applicable codes on the
applicable floors); and (vii) leasehold improvements and/or allowances, including the amounts thereof in renewal leases, and taking into account, in the case of renewal leases (including this Lease), the value of existing leasehold improvements to
the renewal tenant. 
  
 D. The Base Rent shall be
determined as follows: 
  
 1. If Tenant provides
Landlord with its unconditional binding notice of exercise pursuant to Section 31.B above, then, prior to the commencement of the Renewal Term, Landlord shall deliver to Tenant either (a) a good faith written proposal of the Market Rate, or (b)
notice that Landlord has determined in good faith that ninety-five percent (95%) of the Market Rate is less than the Base Rent Floor and, therefore, that the Base Rent for the Renewal Term shall be equal to the Base Rent Floor. Within twenty-one
(21) days after receipt of Landlord’s proposal, Tenant shall notify Landlord in writing (x) that Tenant accepts Landlord’s proposal or (y) that Tenant elects to submit the determination of Market Rate to arbitration in accordance with
Sections 31.D(2) through 31.D(4) below. If Tenant does not give Landlord a timely notice in response to Landlord’s proposal, Tenant shall be deemed to have 

  

 42 








 
elected to submit the determination of Market Rate to arbitration in accordance with Sections 31.D(2) through 31.D(4) below. 
  
 2. If Tenant timely elects to submit the determination of
Market Rate to arbitration, Landlord and Tenant shall first negotiate in good faith in an attempt to determine the Market Rate. If Landlord and Tenant are able to agree within thirty (30) days following the delivery of Tenant’s notice to
Landlord electing arbitration (or if Tenant accepts Landlord’s initial proposal), then such agreement shall constitute a determination of Market Rate for purposes of this Section, and the parties shall immediately execute an amendment to this
Lease stating the Base Rent for the Renewal Term. If Landlord and Tenant are unable to agree on the Market Rate within such negotiating period, then within fifteen (15) days after the expiration of such negotiating period, the parties shall meet and
concurrently deliver to each other in envelopes their respective good faith estimates of the Market Rate (set forth on a net effective rentable square foot per annum basis). If the higher of such estimates is not more than one hundred five percent
(105%) of the lower, then the Market Rate shall be the average of the two. Otherwise, the dispute shall be resolved by arbitration in accordance with Sections 31.D(3) and (4) below. 
  
 3. Within seven (7) days after the exchange of estimates, the parties shall select as an arbitrator an
independent real estate broker with at least five (5) years of experience in leasing commercial office space in the metropolitan area in which the Project is located (a “Qualified Appraiser”). If the parties cannot agree on a
Qualified Appraiser, then within a second period of seven (7) days, each shall select a Qualified Appraiser and within ten (10) days thereafter the two appointed Qualified Appraisers shall select an independent Qualified Appraiser and the
independent Qualified Appraiser shall be the sole arbitrator. If one party shall fail to select a Qualified Appraiser within the second seven (7) day period, then the Qualified Appraiser chosen by the other party shall be the sole arbitrator.

  
 4. Within twenty-one (21) days after
submission of the matter to the arbitrator, the arbitrator shall determine the Market Rate by choosing whichever of the estimates submitted by Landlord and Tenant the arbitrator judges to be more accurate. The arbitrator shall notify Landlord and
Tenant of its decision, which shall be final and binding. If the arbitrator believes that expert advice would materially assist him, the arbitrator may retain one or more qualified persons to provide expert advice. The fees of the arbitrator and the
expenses of the arbitration proceeding, including the fees of any expert witnesses retained by the arbitrator, shall be paid by the party whose estimate is not selected. Each party shall pay the fees of its respective counsel and the fees of any
witness called by that party. 
  
 5. Until the
matter is resolved by agreement between the parties or a decision is rendered in any arbitration commenced pursuant to this Section 31, Tenant’s monthly payments of Base Rent during the Renewal Term shall be in an amount equal to the Base Rent
Floor. Within ten (10) business days following the resolution of such dispute by the parties or the decision of the arbitrator, as applicable, Tenant shall pay to Landlord, or Landlord shall pay to Tenant, the amount of any deficiency or excess, as
the case may be, in the Base Rent theretofore paid. 
  
 E. Tenant’s right to exercise the Renewal Option is personal to, and may be exercised only by, the original named Tenant under this Lease or a Permitted Transferee, and 

  

 43 








 
only if the original named Tenant and/or a Permitted Transferee continues to occupy at least seventy-five percent (75%) of the Premises at the time of such
exercise. If Tenant shall assign this Lease or sublet more than twenty-five percent (25%) of the Premises under a sublease which is effective at any time during the final twelve (12) months of the initial Term to any person other than a Permitted
Transferee, then immediately upon such assignment or subletting, the right to exercise the Renewal Option hereunder shall simultaneously terminate and be of no further force or effect. No assignee or subtenant, other than a Permitted Transferee,
shall have any right to exercise the Renewal Option granted herein. In addition, if Tenant or a Permitted Transferee is in default under this Lease (after any applicable notice and cure period) at the time the Renewal Option is exercised or at any
time thereafter until the commencement of the Renewal Term, or if Tenant or a Permitted Transferee has been in default under this Lease (after any applicable notice and cure period) at any time prior to the exercise of the Renewal Option, Landlord
shall have, in addition to all of its other rights and remedies under this Lease, the right (but not the obligation) to terminate the Renewal Option and to unilaterally revoke the exercise of the Renewal Option, in which case this Lease shall expire
on the Termination Date, unless earlier terminated pursuant to the terms hereof, and Tenant (or a Permitted Transferee) shall have no further rights under this Lease to renew or extend the Term. 
  

 44 








 IN WITNESS WHEREOF, the parties hereto have executed this Lease. 
  

			
	LANDLORD:
	
	CARRAMERICA REALTY CORPORATION,
	 a Maryland corporation

		
	By:	 	 /s/    CHRISTOPHER PEATROSS

	 	 	 Christopher Peatross

	 	 	 Managing Director


  

			
	 Date of Execution:
	 	 10/9/03


  

			
	TENANT:
	
	INTERVIDEO, INC.,
	 a Delaware corporation

		
	By:	 	 /s/    STEVE RO

	Name:	 	 Steve Ro

	Title:	 	 President/CEO

	 	 	 [chairman, president or vice-president]

		
	By:	 	 /s/    RANDY BAMBROUGH

	Name:	 	 Randy Bambrough

	Title:	 	 CFO

	 	 	 [secretary, assistant secretary,
 chief financial officer or assistant treasurer]


  

			
	 Date of Execution:
	 	 

  

 45 








 EXHIBIT A 
  

DESCRIPTION OF PREMISES 
  
 [See Attached] 
  









 EXHIBIT B 
  

RULES AND REGULATIONS 
  
 1. Tenant shall not place anything, or allow anything to be placed near the glass of any window, door, partition or wall which may, in Landlord’s
judgment, appear unsightly from outside of the Project. 
  
 2. The
sidewalks, exits and entrances located in the common areas of the Project shall not be obstructed by Tenant or used by Tenant for any purposes other than for ingress to and egress from the Premises. Tenant shall lend its full cooperation to keep
such areas free from all obstruction and in a clean and sightly condition and shall move all supplies, furniture and equipment as soon as received directly to the Premises and move all such items and waste being taken from the Premises (other than
waste customarily removed by employees of the Building) directly to the shipping platform at or about the time arranged for removal therefrom. 
  
 3. Tenant shall not bring upon, use or keep in the Premises or the Project any kerosene, gasoline or inflammable or combustible fluid or material, or any
other articles deemed hazardous to persons or property. 
  
 4.
Landlord shall have sole power to direct electricians as to where and how telephone and other wires are to be introduced. No boring or cutting for wires is to be allowed without Landlord’s prior written consent. The location of telephones, call
boxes and other office equipment affixed to the Premises shall be subject to Landlord’s prior approval. 
  
 5. No additional locks shall be placed upon any doors, windows or transoms in or to the Premises. Tenant shall not change existing locks or the mechanism
thereof. Upon termination of the Lease, Tenant shall deliver to Landlord all keys and passes for offices, rooms, parking lot and toilet rooms which shall have been furnished Tenant. If the keys so furnished are lost, Tenant shall pay Landlord
therefor. Tenant shall not make, or cause to be made, any such keys and shall order all such keys solely from Landlord and shall pay Landlord for any keys in addition to the two sets of keys originally furnished by Landlord for each lock.

  
 6. Tenant shall not install linoleum, tile, carpet or other
floor covering so that the same shall be affixed to the floor of the Premises in any manner except as approved by Landlord. 
  
 7. No furniture, packages, supplies, equipment or merchandise will be received in the Project, except between such hours as shall be designated by
Landlord. 
  
 8. Without Landlord’s prior written consent,
Tenant shall not use the name of the Project or any picture of the Project in connection with, or in promoting or advertising the business of, Tenant, except Tenant may use the address of the Project as the address of its business. 
  
 9. Tenant assumes full responsibility for protecting the Premises from theft,
robbery and pilferage, which may arise from a cause other than Landlord’s negligence, which includes keeping doors locked and other means of entry to the Premises closed and secured. 
  

 1 








 10. Peddlers, solicitors and beggars shall be reported to the office of the Project or as Landlord
otherwise requests. 
  
 11. Tenant shall not advertise the
business, profession or activities of Tenant conducted in the Project in any manner which violates the letter or spirit of any code of ethics adopted by any recognized association or organization pertaining to such business, profession or
activities. 
  
 12. Tenant shall not make or permit any noise,
vibration or odor to emanate from the Premises, or do anything therein tending to create, or maintain, a nuisance. 
  
 13. Tenant acknowledges that Building security problems may occur which may require the employment of extreme security measures in the day-to-day
operation of the Project. 
  
 Accordingly: 
  
 (a) Landlord may, at any time, or from time to time, or for
regularly scheduled time periods, as deemed advisable by Landlord and/or its agents, in their sole discretion, require that persons entering or leaving the Building or the Project identify themselves to watchmen or other employees designated by
Landlord, by registration, identification or otherwise. 
  
 (b) Tenant agrees that it and its employees will cooperate fully with Project employees in the implementation of any and all security procedures. 
  
 (c) Such security measures shall be the sole responsibility of Landlord, and Tenant shall have no liability
for any action taken by Landlord in connection therewith, it being understood that Landlord is not required to provide any security procedures and shall have no liability for such security procedures or the lack thereof. 
  
 14. Tenant shall not disturb the quiet enjoyment of any other tenant.

  
 15. Landlord may retain a pass key to the Premises and be
allowed admittance thereto at all times to enable its representatives to examine the Premises from time to time and to exhibit the same and Landlord may place and keep on the windows and doors of the Premises at any time signs advertising the
Premises for Rent. 
  
 16. No equipment, mechanical ventilators,
awnings, special shades or other forms of window covering shall be permitted either inside or outside the windows of the Premises without Landlord’s prior written consent, and then only at the expense and risk of Tenant, and they shall be of
such shape, color, material, quality, design and make as may be approved by Landlord. 
  
 17. Tenant shall not during the term of this Lease canvas or solicit other tenants of the Building for any purpose. 
  
 18. Tenant shall not install or operate any phonograph, musical or sound- producing instrument or device, radio receiver or transmitter, TV receiver or
transmitter, or similar device in the Building, nor install or operate any antenna, aerial, wires or other equipment inside or 

  

 2 








 
outside the Building, nor operate any electrical device from which may emanate electrical waves which may interfere with or impair radio or television
broadcasting or reception from or in the Building or elsewhere, without in each instance Landlord’s prior written approval. The use thereof, if permitted, shall be subject to control by Landlord to the end that others shall not be disturbed.

  
 19. Tenant shall promptly remove all rubbish and waste from
the Premises. 
  
 20. Tenant shall not exhibit, sell or offer for
sale, rent or exchange in the Premises or at the Project any article, thing or service, except those ordinarily embraced within the use of the Premises specified in Section 6 of this Lease, without Landlord’s prior written consent. 

 
 21. Tenant shall not overload any floors in the Premises or any public
corridors or elevators in the Building. 
  
 22. Tenant shall not
do any painting in the Premises, or mark, paint, cut or drill into, drive nails or screws into, or in any way deface any part of the Premises or the Building, outside or inside, without Landlord’s prior written consent. 
  
 23. Whenever Landlord’s consent, approval or satisfaction is required
under these Rules, then unless otherwise stated, any such consent, approval or satisfaction must be obtained in advance, such consent or approval may be granted or withheld in Landlord’s sole discretion, and Landlord’s satisfaction shall
be determined in its sole judgment. 
  
 24. Tenant and its
employees shall cooperate in all fire drills conducted by Landlord in the Building. 
  

 3 








 EXHIBIT C 
  

TENANT IMPROVEMENT AGREEMENT 
  
 This Tenant Improvement Agreement (“Agreement”) is an integral part of the Lease dated October 6, 2003 (“Lease”)
relating to certain Premises described therein, and except where clearly inconsistent or inapplicable, the provisions of the Lease are incorporated into this Agreement. Capitalized terms used in this Agreement not otherwise defined herein shall have
the meaning given such terms in the Lease. Landlord and Tenant agree as follows with respect to the Tenant Improvements to be installed in the Premises: 
  
 1. INITIAL TENANT IMPROVEMENTS. 
  
 A. Landlord shall cause to be performed the initial alterations, additions and improvements to the Premises identified on the Approved
Space Plan attached to the Lease as Exhibit C-1 (collectively, the “Tenant Improvements”); provided, however, that Tenant agrees to use commercially reasonable efforts to cooperate with Landlord in minimizing the costs of
such Tenant Improvements, provided that the usability and layout of the Premises is substantially consistent with the Approved Space Plan. Except as otherwise set forth in Exhibit C-1, Landlord shall cause the Tenant Improvements to be
performed subject to and in accordance with Landlord’s standard specifications for the Project (“Project Standard Specifications”), including, but not limited to, the standard building materials which are then being used by
Landlord for the Building. Landlord will provide Tenant with a copy of the Project Standard Specifications upon Tenant’s request. The work of constructing the Tenant Improvements is referred to as “Landlord’s Work”.

  
 B. Following execution of the Lease, Landlord
shall cause to be prepared and delivered to Tenant for Tenant’s review and approval the final working drawings for Landlord’s Work (the “Final Plans”); provided, however, that Tenant’s review and approval of the Final
Plans shall be limited to (1) confirming their consistency with the Approved Space Plan and the Project Standard Specifications and (2) addressing any cost reduction (i.e., value engineering) proposals made by Landlord as provided above.
Tenant’s approval of the Final Plans shall, subject to the foregoing, not be unreasonably withheld, conditioned or delayed. Landlord shall cause Landlord’s Work to be performed substantially as shown on the Final Plans, excepting only
minor variations (i.e., variations which are not inconsistent with the intent of the Final Plans) as Landlord may deem advisable and any Change Orders approved by Landlord, and in compliance with Governmental Requirements. 
  
 2. CHANGE ORDERS. If, prior to the Substantial Completion Date, Tenant shall
request improvements or changes to the Premises in addition to, revision of or substitution for the Tenant Improvements identified on the Approved Space Plan, including, without limitation, any request for above-Building standard finishes or other
detailed specifications (individually or collectively, “Change Order Requests”), Tenant shall deliver to Landlord for its approval plans and specifications for such Change Order Requests. If Landlord does not approve of the plans
for such Change Order Requests, Landlord shall advise Tenant of the revisions required within five (5) business days after Landlord’s receipt of the Change Order Requests. Tenant shall revise and redeliver the plans and specifications to
Landlord within five (5) business days after 

  

 1 








 
Landlord’s advice or Tenant shall be deemed to have abandoned its request for such Change Order Requests. Tenant shall pay for all preparations and
revisions of plans and specifications, and the incremental increase in the cost of construction resulting from all Change Order Requests (as provided in Section 3.A below). 
  
 3. TENANT IMPROVEMENT COSTS. 
  
 A. Landlord shall bear the cost of construction of the Tenant Improvements; provided, however, that (1) Tenant shall bear any increase in
the cost of construction resulting from Change Order Requests agreed upon by Landlord and Tenant; and (2) Tenant shall bear any increase in the cost of construction resulting from any Tenant Delays (as defined in Section 1.A(2) of the Lease).

  
 B. Tenant shall pay to Landlord the costs and
expenses described in Section 3.A above, as reasonably estimated by Landlord, within ten (10) days following presentation to Tenant of an invoice for such costs and expenses. Upon request, Landlord shall supply reasonable supporting documentation
for any such invoice, in each instance within a reasonable time following such request, but Tenant shall not be entitled to delay or withhold payment of any sums invoiced by Landlord, and payment of such sums shall not be deemed a waiver of any
right on the part of Tenant to such reasonable supporting documentation. Any delay resulting from Tenant’s failure to timely pay such invoice or any portion thereof shall be a Tenant Delay. 
  
 4. SUBSTANTIAL COMPLETION. As used herein and in the Lease, the
“Substantial Completion Date” shall be the date that (a) Landlord, its architect, engineer or construction manager determines that Landlord’s Work has been completed, except for (i) finishing details, minor omissions,
mechanical adjustments, and similar items of the type customarily found on an architectural punch-list, the correction or completion of which will not substantially interfere with Tenant’s occupancy and use of the Premises; and (ii) trade
fixtures, workstations, telecommunications or computer cabling or built-in furniture or equipment to be installed by Tenant, and (b) Tenant is legally permitted to occupy the Premises (as evidenced by final inspection and sign-off by the City of
Santa Clara on the job card for Landlord’s Work, or reasonable equivalent) (“Substantial Completion”); provided, however, that as set forth in Section 1.A(2) of the Lease, if Landlord is delayed in completing Landlord’s
Work or in delivering possession of the Premises to Tenant as a result of any Tenant Delay, the Substantial Completion Date shall be deemed to have occurred on the date the Substantial Completion Date would have occurred in the absence of such
Tenant Delay, as reasonably determined by Landlord or Landlord’s architect. 
  

 2 








 EXHIBIT C-1 
  
 APPROVED SPACE PLAN 
  

 3 








 EXHIBIT D 
  

COMMENCEMENT DATE CONFIRMATION 
  
 THIS CONFIRMATION AGREEMENT is entered into as of December 12, 2003 by and between CarrAmerica Realty Corporation, a Maryland corporation
(“Landlord”), and Intervideo, Inc., a Delaware corporation (“Tenant”), with respect to that certain Lease dated as of October 6, 2003 (the “Lease”) respecting certain premises (the “Premises”) located in the
building known as 46420-46430 Fremont Boulevard, Fremont, California. 
  
 Pursuant to Section 1.A of the Lease, Landlord and Tenant hereby confirm and agree that the Commencement Date (as defined in the Lease) is December 5, 2003 and that the Termination Date (as defined in the Lease) is December 31, 2010.

  
 This Confirmation Agreement supplements, and shall be a part
of, the Lease. 
  
 IN WITNESS WHEREOF, Landlord and Tenant have
executed and delivered this Confirmation Agreement as of the day and year first above written. 
  

			
	LANDLORD:
	
	CARRAMERICA REALTY CORPORATION,
	 a Maryland corporation

		
	 By:
	 	 
	 	 	 Christopher Peatross

	 	 	 Managing Director

	 


			
		
	 Date of Execution:
	 	 

  

			
	TENANT:
	
	INTERVIDEO, INC.,
	 a Delaware corporation

		
	 By:
	 	     /S/    STEVE
RO

		
	 Name:
	 	     Steve Ro

		
	 Title:
	 	 


			
		
	 Date of Execution:
	 	 

  

 4 








 EXHIBIT E 
  

ENVIRONMENTAL QUESTIONNAIRE 
  
 As a new tenant of the Project, answer based upon: (1) any existing or previous operations of the same kind which Tenant has conducted elsewhere, and (2)
Tenant’s plans for the new space. For each answer, specify which operation(s) you are describing. 
  
 1. Solid Waste. 
  
 a. Does the facility have an EPA Hazardous Waste generator number? 
  
 b. Does the facility produce Hazardous Waste? Other chemical waste? 
  
 c. Describe each type of waste generated (whether or not hazardous). 
  
 d. If the facility produces hazardous waste, is it classified as a large quantity generator, small quantity generator or
conditionally exempt small quantity generator? 
  
 e. Are
hazardous waste manifests maintained for three years on site? 
  
 f. Please identify the waste disposal contractor. 
  
 2.
Wastewater. 
  
 a. Does the facility produce any
“process wastewater,” meaning any wastewater that has come in contact with chemicals or other materials in process (essentially, any discharge of water other than from sinks and toilets)? 
  
 b. If so, please describe each type of process wastewater produced.

  
 c. Is any water discharged down the floor drains? 

 
 d. Does the facility have a permit for its wastewater discharges?

  
 3. Air Emissions. 
  
 a. Does the facility emit any chemicals or wastes into the air? 

 
 b. Does the facility have an air permit? 
  
 c. Does the facility treat any of its air emissions to remove air pollutants?

  
 d. Describe the ventilation system for the facility.

  

 1 








 4. General. 
  
 a. Has the facility ever been charged with any violation of, or found in violation of any environmental requirements? If yes, please describe. 

 
 b. Are you aware of any testing of soil or groundwater to determine
whether any contamination exists in or around the facility? If so, please provide results. 
  
 c. Please describe any hazardous materials present on site, their respective quantities and the containment measures for those materials. 
  

 2