[Federal Register Volume 83, Number 174 (Friday, September 7, 2018)]
[Notices]
[Pages 45482-45483]
From the Federal Register Online via the Government Publishing Office [www.gpo.gov]
[FR Doc No: 2018-19400]


=======================================================================
-----------------------------------------------------------------------

DEPARTMENT OF VETERANS AFFAIRS

[OMB Control No. 2900-0208]


Agency Information Collection Activity: Department of Veterans 
Affairs Acquisition Regulation; Architect-Engineer Fee Proposal; 
Contractor Production Report; Daily Log and Contract Progress Report

AGENCY: The Office of Management, Department of Veterans Affairs.

ACTION: Notice.

-----------------------------------------------------------------------

SUMMARY: The Office of Management (OM), Department of Veterans Affairs 
(VA), is announcing an opportunity for public comment on the proposed 
collection of certain information by the agency. Under the Paperwork 
Reduction Act (PRA) of 1995, Federal agencies are required to publish 
notice in the Federal Register concerning each proposed collection of 
information,

[[Page 45483]]

including each proposed extension of a currently approved collection, 
and allow 60 days for public comment in response to the notice.

DATES: Written comments and recommendations on the proposed collection 
of information should be received on or before November 6, 2018.

ADDRESSES: Submit written comments on the collection of information 
through Federal Docket Management System (FDMS) at www.Regulations.gov 
or to Rafael Taylor, Office of Acquisition and Logistics (003A2A), 
Department of Veterans Affairs, 810 Vermont Avenue NW, Washington, DC 
20420 or email to <a href="/cdn-cgi/l/email-protection#4113202720242d6f1520382d2e330137206f262e37"><span class="__cf_email__" data-cfemail="2371424542464f0d77425a4f4c516355420d444c55">[email protected]</span></a>. Please refer to ``OMB Control 
No. 2900-0208'' in any correspondence. During the comment period, 
comments may be viewed online through FDMS.

FOR FURTHER INFORMATION CONTACT: Cynthia Harvey-Pryor at (202) 461-
5870.

SUPPLEMENTARY INFORMATION: Under the PRA of 1995, Federal agencies must 
obtain approval from the Office of Management and Budget (OMB) for each 
collection of information they conduct or sponsor. This request for 
comment is being made pursuant to Section 3506(c)(2)(A) of the PRA.
    With respect to the following collection of information, OM invites 
comments on: (1) Whether the proposed collection of information is 
necessary for the proper performance of OM functions, including whether 
the information will have practical utility; (2) the accuracy of OM 
estimate of the burden of the proposed collection of information; (3) 
ways to enhance the quality, utility, and clarity of the information to 
be collected; and (4) ways to minimize the burden of the collection of 
information on respondents, including through the use of automated 
collection techniques or the use of other forms of information 
technology.
    Authority: Public Law 104-13; 44 U.S.C. 3501-3521.
    Title: Department of Veterans Affairs Acquisition Regulation 
(VAAR): VA Form 6298 (formerly 10-6298), Architect-Engineer Fee 
Proposal; VA Form 10101, Contractor Production Report (formerly VA Form 
10-6131, Daily Log and VA Form 10-6001a, Contract Progress Report).
    OMB Control Number: 2900-0208.
    Type of Review: Renewal with changes of a currently approved 
collection.
    Abstract: This Paperwork Reduction Act (PRA) submission seeks 
renewal with changes of Office of Management and Budget (OMB) approval 
No. 2900-0208 as follows:
    <bullet> Replace both existing VA forms 10-6131 (Daily Log 
(Contract Progress Report--Formal Contract)) and 10-6001a (Contract 
Progress Report) with one new form, which combines the intended purpose 
for VA Form 10-6131 and VA Form 10-6001a. The new combined form is now 
read: ``VA Form 10101, Contractor Production Report.''
    <bullet> Renumber VA Form 10-6298 Architect-Engineer Fee Proposal, 
to ``VA Form 6298,'' and revise the contents in the form with updated 
thresholds and FAR citations.
    The above proposed revisions do not change the currently approved 
burden hours. The actual VA forms 10101 and 6298 can be located at VA 
Forms website (http://vaww.va.gov/vaforms/.)
    The Department of Veterans Affairs' Office of Construction and 
Facilities Management (CFM) manage a multi-million-dollar construction 
program that involves the design and construction of medical centers, 
and other VA facilities including building improvements and 
conversions. The actual construction work is contracted out to private 
construction firms.
    VA Form 6298 (formerly 10-6298), Architect-Engineer Fee Proposal: 
The use of this form is mandatory for obtaining the proposal and 
supporting cost or pricing data from the contractor and subcontractor 
in the negotiation of all architect-engineer contracts for design 
services when the contract price is estimated to be $50,000 or more. In 
obtaining architect-engineer services for research study, seismic 
study, master planning study, construction management and other related 
services contracts. A Contractor Production Report is also used but 
supplemented or modified as needed for the particular project type. (VA 
Acquisition Regulation 836.606-71, Architect-engineer's proposal, and 
VAAR 853.236-70.)
    VA Form 10101, Contractor Production Report (formerly VA Form 10-
6131), Daily Log--Formal Contract, and VA Form 10-6001a, Contract 
Progress Report, depending on the size of the contract: Is used to 
record the data necessary to ensure the contractor provides sufficient 
labor and materials to accomplish the contract work. Contractors are 
required to guarantee the performance of the work necessary to complete 
the project. VAAR 852.236-79 details what needs to be addressed by the 
contractor on the Contractor Production Report. Failure to complete 
Contractor Production Report could result in a claim for non-
performance and construction delays against the Government if we were 
unable to collect this information to administer the contract.
    Affected Public: Business or other for-profit and not-for-profit 
institutions.
    Estimated Annual Burden: VA Form 6298--1,000 Burden Hours. VA Form 
10101--4,341 Burden Hours.
    Estimated Average Burden per Respondent: VA Form 6298--4 Hours. VA 
Form 10101--24 Minutes.
    Frequency of Response: On occasion.
    Estimated Number of Respondents: VA Form 6298--250. VA Form 10101--
10,853.

    By direction of the Secretary.
Cynthia D. Harvey-Pryor,
Department Clearance Officer, Office of Quality, Privacy and Risk, 
Department of Veterans Affairs.
[FR Doc. 2018-19400 Filed 9-6-18; 8:45 am]
 BILLING CODE 8320-01-P


</pre><script data-cfasync="false" src="/cdn-cgi/scripts/5c5dd728/cloudflare-static/email-decode.min.js"></script></body>
</html>