Exhibit 4.11.1

  

  

  

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

   

  	 	 	 	 	 	 	 
	AWARD/CONTRACT	 1.	THIS CONTRACT IS A RATED ORDER UNDER DPAS (15 CFR 700)	 	 RATING	 PAGE OF PAGES
	1	         48


  	2. 	CONTRACT (Proc. Inst. Ident) NO.	 3. 	EFFECTIVE DATE	 4.	REQUISITION/PURCHASE REQUEST/PROJECT NO
	HHSO100201500035C	 See Block 20C 	 OS164559


  	5.    ISSUED BY	CODE  	ASPR–BARDA	 6.  ADMINISTERED BY (If other than Item 5)	CODE 	ASPR–BARDA01
	 	 	 	 	 	 
	
          ASPR–BARDA

              200 Independence Ave., S.W.

              Room 640–G

              Washington DC 20201

        	 	ASPR–BARDA 

            330 Independence Ave, SW, Rm G644

            Washington DC 20201	 


  	 	 	 	 	 
	7.   NAME AND ADDRESS OF CONTRACTOR (No., Street, City, Country, State and ZIP Code)	 8.  DELIVERY	 	 
	 	      o FOB ORIGIN 	x OTHER (See below)
	MEDIWOUND LTD 1477616

            MEDIWOUND LTD         42 HAYARKON

            42 HAYARKON

            YAVNE 00812	 9.  DISCOUNT FOR PROMPT PAYMENT
	 	 	 
	 	10. SUBMIT INVOICES

            (4 copies unless otherwise specified)

            TO THE ADDRESS SHOWN IN	 	 ITEM
	CODE 1477616	 FACILITY CODE	 	 	 


  	11. SHIP TO/MARK FOR 	CODE 	HHS/OS/ASPR	12. PAYMENT WILL BE MADE BY 	CODE 	 PSC
	HHS/OS/ASPR

            200 C St SW

            WASHINGTON DC 20201	 	 	PSC

            Program Support Center

            5600 Fishers Lane

            Room 17-21

            Rockville MD-20852	 	 
	 	 	 	 	 	 
	13. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:	 14. ACCOUNTING AND APPROPRIATION DATA
	o 10 U.S.C. 2304 (c) (               ) o 41 U.S.C. 253 (c) (               )	2015.1990002.26201


  	 	 	 	 	 	 	 
	 	 	 	 	 	 
	15A. ITEM NO	15B. SUPPLIES/SERVICES	15C.

            QUANTITY	15D. 

            UNIT	15E. UNIT PRICE	15F. AMOUNT
	 	

            Continued	 	 	 	 
	 	15G. TOTAL AMOUNT OF CONTRACT 	 	 	$40,430,469.00


  16. TABLE OF CONTENTS

  	(X)	SEC.	DESCRIPTION 	 PAGE(S)	(X)	SEC.	DESCRIPTION	 PAGE(S)
	 	PART I - THE SCHEDULE	 	PART II - CONTRACT CLAUSES
	 	A	SOLICITATION/CONTRACT FORM	 	 	I	CONTRACT CLAUSES	 
	 	B	SUPPLIES OR SERVICES AND PRICES/COSTS	 	 	PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACH.
	 	C	DESCRIPTION/SPECS/WORK STATEMENT	 	 	J	LIST OF ATTACHMENTS	 
	 	D	PACKAGING AND MARKING	 	 	PART IV - REPRESENTATIONS AND INSTRUCTIONS
	 	E	INSPECTION AND ACCEPTANCE	 	 	K	REPRESENTATIONS. CERTIFICATIONS AND OTHER STATEMENTS OF OFFERORS	 
	 	F	DELIVERIES OR PERFORMANCE	 	 
	 	G	CONTRACT ADMINISTRATION DATA	 	 	L	INSTRS., CONDS., AND NOTICES TO OFFERORS	 
	 	H	SPECIAL CONTRACT REQUIREMENTS	 	 	M	EVALUATION FACTORS FOR AWARD	 


  CONTRACTING OFFICER WILL COMPLETE ITEM 17 (SEALED-B1D OR NEGOTIATED PROCUREMENT) OR 18 (SEALED-B1D PROCUREMENT) AS APPLICABLE

  	17. o CONTRACTOR’ S NEGOTIATED
            AGREEMENT (Contractor is required to sign this document and return ___________ copies to issuing office.) Contractor agrees to furnish and deliver all items of perform all the services set forth or otherwise identified above and on any
            continuation sheets for the consideration staled herein. The rights and obligations of the parties to this contract shall be subject to and governed by the following documents: (a) this award/contract. (b) the solicitation, if any, and (c) such
            provisions, representations, certifications, and specification as are attached or incorporated by reference herein.	16. þ SEALED-BIO AWARD (Contractor is not required to sign this
              document.) Your bid on Soliciation Number _________________________________________ including the additions or changes made by you which additions or changes are set forth in full above, is hereby accepted as to the items listed above and
            on any continuation sheets. This award consummates the contract which consists of the following documents: (a) the Government’s solicitation and your bid, and (b) this award/contract. No further contractual document is necessary. (Block 18
            should be checked City when awarding a seated-bid contract.)


  	 	 	 	 	 	 	 	 	 
	19A	Name And Title Of Signer (Type of Print)	 20A	NAME OF CONTRACTING OFFICER
	 	Sharon Malka

            Chief Finance Officer

            MediWound Ltd	Gal Cohen

            President & Chief Executive Officer

              MediWound Ltd	 BROOKE T. BERNOLD
	19B.	NAME OF CONTRACTOR 	 	 19C. DATE SIGNED	 20B. 	UNITED STATES OF AMERICA	 	 20C. DATE SIGNED
	BY	/s/ Sharon Malka  /s/ Gal Cohen

        	 	 	 BY	

          /s/ Brooke T. Bernold

          	 	 
	 	(Signature of person authorized to sign)	 	9/29/2015	 	(Signature of the Contracting Officer)	 	9/29/2015


  	AUTHORIZED FOR LOCAL REPRODUCTION 

            Previous edition is NOT usable	 	STANDARD FORM 26 (Rev. 5/2011)

            Prescribed by GSA - FAR (48 CFR) 53.214(a)


   

  
  
    	 


  

  
    	 


  

  
   

  

   

  PART I – THE SCHEDULE

   

  SECTION B – SUPPLIES OR SERVICE AND PRICE / COST

   

  Non-Surgical Debridement for Definitive Care of Burn Injuries 

   

  ARTICLE B.1.   BRIEF DESCRIPTION OF SUPPLIES OR SERVICES

   

  Mediwound Ltd. is developing NexoBrid, a unique Debridement product that enables clinicians to restore, normal
      skin when treating partial thickness or full thickness burns. The product has the potential to greatly improve the patient’s quality of life while reducing hospital stays and the need for reconstructive surgery. This product could find utility in
      day-to-day care, while simultaneously improving our capability to respond to mass casualty incidents.

   

  Under the base period-of-performance, Mediwound Ltd. will further enhance their product to improve its
      commercial viability through the FDA approval process and potentially complete an initial purchase, storage, and delivery of product. The contract options may be exercised to perform follow-on studies as directed by the FDA, perform additional
      studies which further extend the ability to protect children and the elderly population, and purchase additional treatment courses.

   

  The Research and Development (R&D) effort will progress in specific stages that cover the base performance
      segment and several options as specified in this contract. The period of performance for the base period is 60 months.

   

  ARTICLE B.2.   BASE PERIOD

   

  	CLIN	Period of 

              Performance	Supplies/ Services	Total Est. 

              Cost	Fixed Fee 

              (7%)	Total Cost 

              Plus Fixed 

              Fee
	 	 	COST REIMBURSEMENT	 	 	 
	0001 

            (Base)	09/28/2015 –

            09/27/2020	Licensure,


              approval, and clearance of product through the FDA	$22,693,160	$1,262,501	$23,955,661

            (Funded)
	 	 	FIRM FIXED PRICE	 	 	 
	CLIN	Period


                of 

              Performance	Supplies/ Services	Units (# of 

              Product)	Unit Price 

              ($)	Total ($)
	0002 

            (Base)	09/28/2017


              – 09/27/2019*(* see advanced understanding h.)	Initial Purchase, storage, and
              delivery of product	10,588	$1,052 

              (includes 

              VMI)	$11,138,576 

              (Funded)
	0002 

              (Base)	09/28/2019


              –

              09/27/2020	Initial Purchase, storage, and
              delivery of product	5412	$986

              (includes 

              VMI)	$5,336,232

              (Funded)
	Total CLINS 1&2	09/28/2015


              –

              09/27/2020	See Above Descriptions	 	 	$40,430,469

              (Funded)


   

  

  
  
    	2


  

  
    	 


  

  
   

  ARTICLE B.3.   OPTION PRICES

    

  	CLIN	Period of 

                Performance	Supplies/ Services	Units (# of 

                Product)	Unit Price 

                ($)	Total ($)
	 	 	FIRM FIXED PRICE	 	 	 
	
          0003

          

          (Option

          

          Quantity)

        	60 Months	Phase IV post marketing commitments /Requirements (This is
            an option that may or may not be exercised during the base period as determined by the need and as established by the FDA)	N/A	N/A	$5,639,146 

            (Not Funded)
	 	 	COST REIMBURSEMENT	 	 	 
	CLIN	Period of 

              Performance		Total Est. Cost	Fixed Fee 

              (7%)	Total Cost 

              Plus Fixed 

              Fee
	0004 A (Option Quantity)	60 Months	Pediatric Study (This is an option that may or may not be
            exercised during the base period for expansion of the label indication with guidance from the FDA)	$11,237,608	$688,011	$11,925,619

            (Not Funded)
	0004 B (Option Quantity)	60 Months	Burn Induced Compartment Syndrome Study(BICS) (This is an
            option that may or may not be exercised during the base period for expansion of the label indication with guidance from the FDA)	$4,185,894	$261,819	$4,447,713

            (Not Funded)
	 	 	FIRM FIXED PRICE	 	 	 
	CLIN	Period of 

                Performance	Supplies/ Services	Units (# of 

                Product)	Unit Price 

                ($)	Total ($)
	
          0005A

          

          (Option

          

          Quantity)

          

        	60 Months	US Facility validation for manufacture of product (in USA)	N/A	N/A	$4,819,074 

            (Ceiling Not 

            Funded)
	
          0005B

          

          (Option

          

          Quantity)

          

        	12 Months	Additional Surge Capacity 1 to 23,530 units	1 to 23,530	$986	$23,200,580 

            (Ceiling Not 

            Funded)
	
          0005B

          

          (Option

          

          Quantity)

          

        	12 Months	Additional Surge Capacity 23,531 to 47,060 units	23,531 to 

            47,060	$950	$22,353,500 

            (Ceiling Not 

            Funded)
	Total 

              CLINs  3-5	60 Months	See Above Descriptions	 	 	
          $72,385,632

          

          (Not

          

          Funded)

          

        


    

  
  
    	3


  

  
    	 


  

  
  

   

  ARTICLE B.4.    LIMITATIONS APPLICABLE TO DIRECT COSTS

   

  a.    Items Unallowable Unless Otherwise Provided

   

  Notwithstanding the clause FAR 52.216-7, Allowable Cost and Payment, incorporated in this contract,
      the costs of the following items or activities shall be unallowable as direct costs unless authorized in writing in advance by the Contracting Officer:

   

  	 	1.	Acquisition, by purchase or lease, of any interest in real property;
	 	 	 
	 	2.	Special rearrangement or alteration of facilities;
	 	 	 
	 	3.	Purchase or lease of any item of general purpose office furniture or office equipment regardless of dollar value. (General purpose equipment is defined as any items of personal
            property which are usable for purposes other than research, such as office equipment and furnishings, pocket calculators, etc.);
	 	 	 
	 	4.	Travel to attend general scientific meetings;
	 	 	 
	 	5.	Unapproved foreign travel
	 	 	 
	 	6.	Consultant costs, except costs incurred under firm-fixed price consultant agreements valued at $150,000 or less are allowable without prior authorization.
	 	 	 
	 	7.	Subcontracts; except costs incurred under firm-fixed price subcontracts valued at $150,000 or less are allowable without prior authorization.
	 	 	 
	 	8.	Patient care costs;
	 	 	 
	 	9.	Accountable Government property (defined as both real and personal property with an acquisition cost of $1,000 or more and a life expectancy of more than two years) and “sensitive items”
            (defined as items of personal property, supplies and equipment that are highly desirable and easily converted to personal use), regardless of acquisition value.
	 	 	 
	 	10.	Printing Costs (as defined in the Government Printing and Binding Regulations).
	 	 	 
	 	11.	Light Refreshment and Meal Expenditures - Requests to use contract funds to provide light refreshments and/or meals to either federal or nonfederal employees
            must be submitted to the Contracting Officer’s Representative (COR), with a copy to the Contracting Officer, at least six (6) weeks in advance of the event and are subject to “HHS Policy on Promoting Efficient Spending: Use of Appropriate
            Funding for Conferences and Meeting, Food and Promotional Items and Printing and Publications.” The request shall contain the following information: (a) name, date, and location of the event at which the light refreshments and/or meals will be
            provided; (b) a brief description of the purpose of the event; (c) a cost breakdown of the estimated light refreshments and/or meals costs; (d) the number of nonfederal and federal attendees receiving light refreshments and/or meals; and (e) if
            the event will be held at a government facility.
	 	 	 
	 	12.	Meeting room or conference space used for face to face meetings with USG staff in the performance of this contract. Justification for why the meeting cannot be held at a government facility
            must be provided. COA requests must be made at least (2) two weeks prior to meeting date.


   

  
  
    	4


  

  
    	 


  

  
  

   

  b.     Travel Costs

    

  	 	1.	Travel incurred by the Prime Contractor in direct performance of this contract shall require and be consistent with advance written approval by the Contracting Officer
            for expenditures such as (transportation, lodging, subsistence, and incidental expenses).
	 	 	 
	 	2.	FAR 52.247-63 – Preference for U.S.-Flag Air Carriers is applicable.
	 	 	 
	 	3.	The Contactor shall invoice and be reimbursed for all travel costs in accordance with FAR 31.703 and FAR 31.205-46, Contracts with Commercial Organizations, Travel Costs.
	 	 	 
	 	4.	Requests for foreign travel must be submitted at least six weeks in advance and shall contain the following:
	 	 	(i)    Meeting(s) and place(s) to be visited, with costs and dates;
	 	 	(ii)   Names(s) and title(s) of Contractor personnel to travel and their functions in the contract project;
	 	 	(iii)  Contract purpose to be served by the travel;
	 	 	(iv)  How travel of Contractor personnel will benefit and contribute to accomplishing the contract project, or will otherwise justify the
            expenditure of AMCG contract funds;
	 	 	(v)   How such advantages justify the costs for travel and absence from the project of more than one person if such are suggested; and
	 	 	(vi)  What additional functions may be performed by the travelers to accomplish other purpose of the contract and thus further benefit the
            project.


   

  ARTICLE B.5.   ADVANCE UNDERSTANDINGS

   

  		 	a.	Subcontracts and Consultants


   

  Award of any FFP subcontract or FFP consulting agreement in excess of $150,000 or any cost reimbursement
        subcontract or consulting agreement shall not proceed without the prior written consent of the Contracting Officer via a Contracting Officer Authorization (COA) Letter. COA letters will only be issued upon review of the supporting documentation
      required by FAR Clause 52.244-2, Subcontracts. After receiving written consent of the subcontract by the contracting Officer, a copy of the signed, executed subcontract and consulting agreement shall be provided to the Contracting Officer within ten
      (10) days.

   

  		 	b.	Site Visits, Inspections and General Audits


   

  At the discretion of the USG and independent of activities conducted by the Contractor, with 48 hours’ notice to the
      Contractor, the USG reserves the right to conduct site visits and inspections on an as needed basis, including collection of product samples and intermediates held by the Contractor, or subcontractor. In case of subcontractor visits and inspections
      that are independent of activities conducted by the Contractor, the USG shall demonstrate cause for such visit and/or inspection. All costs reasonably incurred by the Contractor and subcontractor for such visit and/or inspection shall be allowable
      costs. The Contractor shall coordinate these visits and shall have the opportunity to accompany the USG on any such visits. Under time-sensitive or critical situations, the USG reserves the right to suspend the 48 hour notice to the Contractor. If
      the Government, Contractor, or other party identifies any issues during an audit, the Contractor shall capture the issues, identify potential solutions, and provide a report to the Government for review and acceptance.

   

  

  		·	If issues are identified during the audit, Contractor shall submit a report to the CO and COR within 10 business days detailing the finding and
            corrective action(s) of the audit.


  

  		·	COR and CO will review the report and provide a response to the Contractor within 10 business days.


  

  		·	Once corrective action is completed, the Contractor will provide a final report to the CO and COR within 10 business days.


   

  
  
    	5


  

  
    	 


  

  
  

  

  

   

  c.    QA Audits

  BARDA reserves the right to participate in QA audits.
      Upon completion of the QA audit the Contractor shall provide a report capturing the findings, results, and next steps in proceeding with any potential subcontractors. If action is requested for a subcontractor, detailed corrective and preventative
      plans for addressing areas of non-conformance to ICH and FDA regulations for GLP, GMP, or GCP guidelines, as identified in the audit report, must be provided to BARDA for review and acceptance. The Contractor shall provide responses from the
      subcontractors to address these concerns and plans for corrective action execution.

  		•	Contractor shall notify CO and COR of upcoming, ongoing, or recent audits/site visits of subcontractors as part of weekly communications.


  		•	Contractor shall notify the COR and CO within 5 business days of report completion. The Contractor shall complete the report within 60
            days of the audit/site visit, or as negotiated with the COR in writing dependent upon the audit findings.


  d.    Man-in-Plant

  At the discretion of the Government and seven (7) days advance
      notice to the Contractor in writing from the Contracting Officer, the Government may place a man-in-plant in the Contractor’s facility, who shall be subject to the Contractor’s policies and procedures regarding security and facility access at all
      times while in the Contractor’s facility. As determined by federal law, no Government representative shall publish, divulge, disclose, or make known in any manner, or to any extent not authorized by law, any information coming to him in the course of
      employment or official duties, while stationed in a contractor plant.

  e.    Confidential Treatment of Sensitive Information

  The Contractor shall, to the extent permitted by law, guarantee strict
      confidentiality of the information/data that is provided by the Government during the performance of the contract. The Government has determined that the information/data that the Contractor will be provided during the performance of the contract is
      of a sensitive nature.

  Disclosure of the information/data, in whole or in part, by the
      Contractor can only be made after the Contractor receives prior written approval from the Contracting Officer. Whenever the Contractor is uncertain with regard to the proper handling of information/data under the contract, the Contractor shall obtain
      a written determination from the Contracting Officer.

  Notwithstanding the foregoing, such information/data shall not be deemed of
      a sensitive nature with respect to the Contractor for purposes of this contract if such information/data: (a) was already known to the Contractor; (b) was generally available or known, or was otherwise part of the public domain, at the time of its
      disclosure to the Contractor; (c) became generally available or known, or otherwise became part of the public domain, after its disclosure to, or, with respect to the information/data by, the Contractor through no fault of the Contractor; (d) was
      disclosed to the Contractor, other than under an obligation of confidentiality or non-use, by a third party who had no obligation to the Government that controls such information/data not to disclose such information/data to others; or (e) was
      independently discovered or developed by the Contractor, as evidenced by its written records, without the use of information/data belonging to the Government.

  

  
  
    	6 


  

  
    	 


  

  
  

  The Contractor may disclose information/data of
      a sensitive nature provided by the Government to the extent that such disclosure is: (a) made in response to a valid order of a court of competent jurisdiction (b) otherwise required by law, (c) made by the Contractor to the Regulatory Authorities as
      required in connection with any filing, application or request for Regulatory Approval; provided, however, that reasonable measures shall be taken to assure confidential treatment of such information/data

  f.    Emergency Use Authorization (EAU)

  The Contractor shall be responsible for generating the data to support
      the USG’s filing of a Pre-Emergency Use Authorization (Pre-EUA) package for use of the product prior to FDA licensure or approval during a declared emergency, declared potential emergency, or identification of material threat under an Emergency Use
      Authorization (EUA).

  The Contractor commits to supporting the potential use of the product
      under a pre-EUA package as submitted by BARDA or the CDC/SNS. The Contractor shall supply BARDA or the CDC/SNS with the data needed to support such a submission, including expanded access INDs, right to hold product, right of reference to the
      Contractor’s Investigational New Drug (IND), or other application that contains the supporting data. The Contractor shall address any FDA comments on all pre-EUA packages as applicable. The Contractor shall maintain and update, as required by the
      FDA, all required regulatory documentation (investigator brochure, regulatory binder, etc.), that will be used to support use under EUA and approval/licensure.

  Any product which has not received FDA approval or licensure, but has
      completed submission of the Pre-EUA package and has met the three (3) criteria listed below may be considered for procurement at the discretion of the USG. The Contractor would be required to demonstrate the three (3) essential criteria
      listed below for consideration of procurement of any unapproved products by seeking a COA. The COA shall include a product delivery schedule for consideration and the following:

  		•	Substantial evidence, including a validated process, of the Contractor’s ability to manufacture a product that would be identical to the commercial scale as
            required for product approval or licensure. A clear understanding of the outstanding risks, if any, for approval or licensure must be demonstrated.


   

  		•	Completion of pivotal clinical studies with substantial evidence of safety and efficacy for the indicated use. A list of outstanding activities and targets for completion, adverse
            events/safety profile which do not pose unusual risks or challenges for FDA approval or licensure shall be provided.


   

  		•	Substantial evidence of product familiarity/acceptance for use in burn centers. The Contractor shall provide a list of burn centers familiar with the product, feedback received, and
            corrective actions required to address any concerns to ensure effective use of the product by burn care providers unfamiliar with the product. Evidence of the company’s ability to educate such providers on the use of the product (as allowed
            within the constraints of law) will be useful.


  

  

   

  A tentative delivery schedule of product delivery to the inventory
      (acceptable as in the Quality Agreement) shall be required as part of the COA. The delivery schedule shall be updated periodically as necessary.

   

  

  
  
    	7 


  

  
    	 


  

  
   

  For information concerning EUA, please
      consult 

      http://www.fda.gov/RegulatoryInformation/Guidances/ucm 125127 and

  http://www.fda.gov/EmergencyPreparedness/Counterterrorism/MedicalCountermeasures/MCMLegalRegulatoryandPolicyFramework/ucml82568.htm

  g.    Sharing of contract deliverables within United
      States Government (USG)

  In an effort to build a robust medical
      countermeasure pipeline through increased collaboration, BARDA may share technical deliverables with USG entities responsible for Medical Countermeasure Development. In accordance with recommendations from the Public Health Emergency Medical
      Countermeasure Enterprise Review, agreements established in the Integrated Portfolio’s Portfolio Advisory Committee (PAC) Charter, and agreements between BARDA and the Department of Defense and the National Institutes of Health, BARDA may share
      technical deliverables and data created in the performance of this contract with colleagues within the Integrated Portfolio. This advance understanding does not authorize BARDA to share financial information outside HHS. The Contractor is advised to
      review the terms of FAR 52.227-14, Rights in Data – General, regarding the Government’s rights to deliverables submitted during performance as well as the Government’s rights to data contained within those deliverables.

  h.    Overtime Compensation

  No overtime (premium) compensation is
      authorized under the subject contract. Billing of actual hours should be limited to total productive hours in a month.

  i.     Option CLINS

  The USG reserves the right to
      re-negotiate the option CLINS based availability of funds and feedback received from the FDA.

  j.     Contract Number Designation

  On all correspondence submitted under
      this contract, the Contractor agrees to clearly identify the contract number that appears on the face page of the contract as follows:

  HHS100201500035C

  h.    Quality Agreement

  The Quality Agreement shall specify the
      responsibilities of both the Contractor and the USG (i.e. – CDC/SNS-Quality Control and BARDA) for event-driven and product shipping, receiving, acceptance into the inventory and/or custody by the USG. This document shall be drafted and signed by all
      parties prior to the commencement of product procurement and acceptance, transport and custody of the product under the VMI/DMI or the CDC/SNS. The Contractor shall provide documentation and resolution for all concerns raised by USG and commits to
      cooperation in execution of this agreement.

  

  
  
    	8 


  

  
    	 


  

  
  

  SECTION C – DESCRIPTION/SPECIFICATIONS/WORKSTATEMENT

  C.1.    STATEMENT OF WORK

   

  ARTICLE C.1.    STATEMENT OF WORK

  Independently and not as an agent of the Government,
      the Contractor shall furnish all the necessary services, qualified personnel, material, equipment, and facilities not otherwise provided by the Government as needed to perform the Statement of Work dated September 28, 2015 set forth in SECTION J -
      List of Attachments, attached hereto and made a part of the contract.

  ARTICLE C.2.    REPORTING REQUIREMENTS

  See Section F for specific reporting requirements.

  All reports required herein shall be submitted in
      electronic format. All paper/hardcopy documents/reports submitted under this contract shall be printed or copied, double-sided, on at least 30 percent post-consumer fiber paper, whenever practicable, in accordance with FAR 4.302(b).

  ARTICLE C.3.    TWICE MONTHLY CONFERENCE CALLS

  A conference call between the Contracting Officer’s
      Representative and the Contractor’s Project Leaders/delegates and designees shall occur twice-monthly or as directed by the Contracting Officer and Contracting Officer’s Representative. During this call the Contractor’s Project Leaders/delegates and
      designees will discuss the activities since the last call, any problems that have arisen and the activities planned until the next call takes place. The Contractor’s Project Leaders/delegates may choose to include other key personnel on the
      conference call to give detailed updates on specific projects or this may be requested by the Contracting Officer’s Representative.

  ARTICLE C.4.    PROJECT MEETINGS

  The Contractor shall participate in Project Meetings to
      coordinate the performance of the contract, as requested by the Contracting Officer’s Representative. These meetings may include face-to-face meetings with AMCG/BARDA in Washington, D.C. and at work sites of the Contractor. Such meetings may include,
      but are not limited to, meetings of the Contractor to discuss study designs, site visits to the Contractor’s facilities, and meetings with the Contractor and HHS officials to discuss the technical, regulatory, and ethical aspects of the program.
      Subject to the data rights provisions in this contract, the Contractor will provide data, reports, and presentations to groups of outside experts and USG personnel as required by the Contracting Officer and Contracting Officer’s Representative in
      order to facilitate review of contract activities.

   

  
  
    	9 


  

  
    	 


  

  
    

  SECTION D – PACKAGING, MARKING AND SHIPPING

  All deliverables required under this contract shall be packaged, marked and
      shipped in accordance with Government specifications. At a minimum, all deliverables shall be marked with the date, contract number and Contractor name. The Contractor shall guarantee that all required materials shall be delivered in immediate usable
      and acceptable condition.

  The US storage facility will be a subcontractor that must be acceptable to the
      USG and approved under a COA. Issuance of a COA shall meet the conditions specified in the Quality Agreement between BARDA, CDC and MediWound.

   

  

  
  
    	10 


  

  
    	 


  

  
   

  SECTION E – INSPECTION AND ACCEPTANCE

  ARTICLE E.1.  INSPECTION AND ACCEPTANCE

  The Contracting Officer or the duly authorized
      representative will perform inspection and acceptance of materials and services to be provided under this contract.

  For the purpose of this SECTION E, the designated
      Contracting Officer’s Representative (COR) is the authorized representative of the Contracting Officer. The COR will assist in resolving technical issues that arise during performance. The COR however is not authorized to change any contract terms or
      authorize any changes in the Statement of Work or modify or extend the period of performance, or authorize reimbursement of any costs incurred during performance. The Contractor is advised to review FAR 52.243–1 Changes – Fixed Price Contracts
      Alternate V and FAR 52.243-2 Changes–Cost reimbursement contracts Alternative V, which is incorporated by reference into this contract in ARTICLE I.1.

  Inspection and acceptance will be performed at:

  Office of Acquisition Management, Contracts, and Grants (AMCG) 

      Office of the Assistant Secretary for Preparedness and Response 

      U.S. Department of Health and Human Services 

      200 C St. SW 

      Washington, D.C. 20024

  Acceptance may be presumed unless otherwise indicated in
      writing by the Contracting Officer or the duly authorized representative within 30 days of receipt.

  The contract incorporates the following clause by
      reference with the same force and effect as if it were given in full text. Upon request, the Contracting Officer will make its full text available.

   

  FAR 52.246-4, Inspection of Services - Fixed Price (August 1996)

   

  FAR 52.246-5, Inspection of Services - Cost-Reimbursement (April 1984)

   

  FAR 52.246-9, Inspection of Research and Development (Short Form) (April 1984)

   

  FAR 52.246-16, Responsibility for Supplies (April 1984)

   

  
  
    	11 


  

  
    	 


  

  
  

  SECTION F – DELIVERIES OR PERFORMANCE

  ARTICLE F.1.   PERIOD OF PERFORMANCE

  The period of performance for this contract shall be from September 28, 2015
      through September 27, 2020. The period of performance for the base period of this contract shall be consistent with the dates set forth in SECTION B. If the Government exercises option(s), the period of performance will be extended as described under
      in SECTION B of this contract.

  ARTICLE F.2.   REPORTING REQUIREMENTS

  In all cases the reports are intended to provide sufficient detail to
      understand the Contractor’s approach and progress to addressing the technical requirements. The reports supplement, and do NOT replace, routine (i.e. daily) communication between the COR and project manager and/or their designee(s) regarding project
      plans and progress.

  A.   Monthly Progress Report

  This report shall include a description of the activities during the
      reporting period and the activities planned for the ensuing reporting period. The first reporting period consists of the first full month of performance plus any fractional part of the initial month. Thereafter, the reporting period shall consist of
      each calendar month.

  The Contractor shall submit a Monthly Progress Report on or before the
      15th calendar day following the last day of each reporting period and shall include the following:

  Title Page: The title page for this report
      shall include the contract number and title; the type of report and period that it covers; the Contractor’s name, address, telephone number, fax number, and e-mail address; and the date of submission.

   

  Distribution List: A list of individuals receiving the Technical
      Progress report.

   

  Progress:

   

  SECTION I - An introduction covering the purpose and scope of the contract
      effort.

   

  SECTION II Part A: SUMMARY - A description or table summarizing ongoing
      activities.

  

  SECTION II Part B: MANAGEMENT AND ADMINISTRATIVE UPDATE – This section
      shall include a description of all meetings, conference calls, etc. that have taken place during the reporting period. Include progress on administration and management issues (e.g. evaluating and managing subcontractor performance and personnel
      changes). Please include all Quality Management System, Quality Control, and Quality Assurance updates as part of this report or as requested by the COR.

  SECTION II Part C: TECHNICAL PROGRESS – This section shall document the
      results of work completed and costs incurred during the period covered in relation to the proposed progress, effort, and budget. The report shall be in sufficient detail to explain comprehensively the results achieved.

  SECTION II Part D: ISSUES – This section shall include a description of
      problems encountered and proposed corrective action; differences between planned and actual progress; why the differences have occurred and what corrective actions are planned; and if a project activity is delinquent, then what corrective action
      steps are planned. Revised timelines shall be provided.

   

  
  
    	12 


  

  
    	 


  

  
  

  

  SECTION II Part E: PROPOSED WORK – This section shall include a summary of
      work proposed as a rolling three (3) month forecast for the next reporting period, by a certain date, and by whom.

   

  SECTION II Part F: MANUFACTURING AND SUPPLY CHAIN MANAGEMENT – This section
      shall include a summary of the manufacturing and supply-chain related activities. Also include in this section updates to the production plan, capacity projections, stability results, inventory and shipment/distribution information.

  

  Invoices: Summary of any invoices submitted during the reporting
      period.

   

  A Monthly Progress Report will not be required in the same month Annual or
      Final Technical Progress Reports are due.

  

  B.    Annual Progress Report

  This report shall include a summation of the activities during the reporting
      period, and the activities planned for the ensuing reporting period. The first reporting period consists of the first full year of performance plus any fractional part of the initial year. Thereafter, the reporting period shall consist of each
      calendar year.

   

  The Contractor shall submit an Annual Progress Report on or before the 30th
      calendar day following the last day of each reporting period and shall include the following:

   

  Title Page: The title page for this report shall include the contract
      number and title; the type of report and period that it covers; the Contractor’s name, address, telephone number, fax number, and e-mail address; and the date of submission.

   

  Distribution List: A list of individuals receiving the Technical
      Progress report.

   

  Progress:

   

  SECTION I - An introduction covering the purpose and scope of the contract
      effort.

   

  SECTION II Part A: SUMMARY - A description or table summarizing ongoing
      activities.

   

  SECTION II Part B: MANAGEMENT AND ADMINISTRATIVE UPDATE – This section shall
      include a description of all meetings, conference calls, etc. that have taken place during the reporting period. Include progress on administration and management issues (e.g. evaluating and managing subcontractor performance and personnel changes).
      Please include all Quality Management System, Quality Control, and Quality Assurance updates as part of this report or as requested by the COR.

   

  SECTION II Part C: TECHNICAL PROGRESS – This section shall document the
      results of work completed and costs incurred during the period covered in relation to proposed progress, effort, and budget. The report shall be in sufficient detail to explain comprehensively the results achieved.

   

  SECTION II Part D: ISSUES – This section shall include a description of
      problems encountered and proposed corrective action; differences between planned and actual progress; why the differences have occurred and what corrective actions are planned; and if a project activity is delinquent, then what corrective action
      steps are planned. Revised timelines shall be provided.

   

  
  
    	13 


  

  
    	 


  

  
  

  

   

  

  SECTION II Part E: PROPOSED WORK – This section shall include a summary of work proposed as a rolling three (3) month forecast for the next reporting period, by a certain date,
    and by whom.

   

  SECTION II Part F: MANUFACTURING AND SUPPLY CHAIN MANAGEMENT – This section shall include a summary of the manufacturing and supply-chain related activities. Also include in
    this section updates to the production plan, capacity projections, stability results, inventory and shipment/distribution information.

   

  Invoices: Summary of any invoices submitted during the reporting period.

   

  An Annual Progress Report will not be required for the period when the Final Technical Progress Report is due.

   

  		C.	Draft Final Report and Final Report


   

  These reports are to include a summation of the work performed and results obtained for execution of various studies or technical work packages during the entire contract period
    of performance. This report shall be in sufficient detail to describe comprehensively the results achieved. The Draft Final Progress Report shall be due forty-five (45) calendar days prior to the expiration date of the contract and the Final Progress
    Report is due no later than 30 days following the expiration date of the contract. The report shall conform to the following format:

   

  Title Page: The title for these reports shall include the contract number and title; the type of report and period that it covers; the Contractor’s name, address,
    telephone number, fax number, and e-mail address; and the date of submission.

   

  Distribution List: A list of individuals receiving the Technical Progress report.

   

  Progress:

   

  SECTION I: EXECUTIVE SUMMARY - Summarize the purpose and scope of the contract effort including a summary of the major accomplishments relative to the specific activities set
    forth in the Statement of Work.

   

  SECTION II: RESULTS - A detailed description of the work performed and the results obtained including all expenses for the entire contract period of performance.

   

  		D.	FDA Regulatory Agency Correspondence, Meeting Summaries, and Submissions.


   

  		a.	Within five business days of any formal meeting with the FDA or other regulatory agency, the Contractor shall forward the initial draft minutes to BARDA. The Contractor shall forward the final minutes when available.


   

  		b.	Within five business days of any informal meeting with the FDA or other regulatory agency, the Contractor shall forward the initial draft minutes to BARDA. The Contractor shall forward the final minutes when available and if applicable.


   

  		c.	The Contractor shall forward the dates and times of any meeting with the FDA and other regulatory agencies to BARDA as soon as the meeting times are known and make arrangements for appropriate BARDA staff to attend the meetings.


   

  		d.	The Contractor shall provide BARDA the opportunity to review and comment upon any documents to be submitted to the FDA or other regulatory agency. The Contractor shall provide BARDA with five (5) business days in which to review and provide
          comments back to the Contractor prior to the Contractor’s submission to the FDA.


   

  

  
  
    	14


  

  
    	 


  

  
   

  		e.	The Contractor shall forward Standard Operating Procedures (SOPs) upon request from COR.


   

  		f.	The Contractor shall provide raw data and/or specific analysis of data generated with USG funds upon request from the COR.


   

  		g.	The Contractor shall notify the Contracting Officer’s Representative and Contracting Officer within 24 hours of all FDA arrivals to conduct site visits/audits by any regulatory agency. The Contractor shall provide the USG with an exact copy
          (non-redacted) of the FDA Form 483 and the Establishment Inspection Report (EIR). The Contractor shall provide the Contracting Officer’s Representative and Contracting Officer copies of the plan for addressing areas of non-conformance to FDA
          regulations for GLP guidelines as identified in the audit report, status updates during the plans execution, and a copy of all final responses to the FDA. The Contractor shall also provide redacted copies of any FDA audits received from
          subcontractors that occur as a result of this contract or for this product. The Contractor shall make arrangements with the COR for the appropriate BARDA representative(s) to be present during the final debrief by the regulatory inspector.


   

  		E.	Other Requirements/Deliverables


   

  		a.	Integrated Master Project Plan

          The Contractor shall provide an Integrated Master Project Plan (including tabular and Gantt forms) to BARDA that clearly indicates the critical path to annual deliverables and Work Breakdown Structure (WBS) elements. Attention shall be placed on
          providing sufficient turnaround time for the USG (BARDA, FDA, and CDC) for review of critical documentation. The Contractor shall integrate to demonstrate interdependencies among all CLINS. The Integrated Master Project Plan shall be incorporated
          into any potential contract and will be used to monitor performance of the contract. This report shall be due within 90 days of contract award. Updates shall be due as requested by the COR or Co- COR.


   

  		i.	Critical Path Milestones

          The Integrated Master Project Plan shall outline key, critical path milestones, with “Go/No Go” decision criteria (entrance and exit criteria for each phase of the project). This report shall be due within 90 days of contract award. Updates shall
          be due as requested by the COR or Co-COR.


   

  		ii.	Work Breakdown Structure

          The USG has provided a Contract Work Breakdown Structure (CWBS) template (See http://www.phe.gov/about/amcg/contracts/Pages/toolkit.aspx) and the Contractor shall further delineate the CWBS to Level 5 as part of their Integrated Master
          Project Plan. The WBS shall be discernable and consistent. BARDA may require Contractor to furnish WBS data at the work package level or at a lower level if there is significant complexity and risk associated with the task. This report shall be
          due within 90 days of contract award. Updates shall be due as requested by the COR or Co-COR.


   

  

  
  
    	15


  

  
    	 


  

  
   

  		iii.	Risk Mitigation Plan/Matrix

          The Contractor shall develop and maintain a risk management plan that highlights potential problems and/or issues that may arise during the life of the contract, their impact on cost, schedule and performance, and appropriate remediation plans.
          This plan shall reference relevant WBS/SOW elements where appropriate. The USG has provided a Risk Mitigation Matrix template (See http://www.phe.gov/about/amcg/contracts/Pages/toolkit.aspx) to be completed by any prospective Contractor.
          This report shall be due within 90 days of contract award. Updates shall be due as requested by the COR or Co-COR.


   

  		b.	Technology Packages

          Technology packages developed under the contract that includes complete protocols must be submitted at the request of the BARDA Contracting Officer’s Representative. See FAR clauses 52.227-11, Patent Rights-Ownership by the Contractor, and
          52.227-14, Rights in Data. This report shall be due upon request from the COR or Co-COR.


   

  		c.	Annual/Final Invention Report

          All reports and documentation required by FAR Clause 52.227-11, Patent Rights-Ownership by the Contractor, including, but not limited to, the invention disclosure report, the confirmatory license, and the Government support certification. An
          Annual Invention Report shall be due on or before the 30th calendar day after the completion of each reporting period. A Final Invention Report (see FAR 27.303 (b)(2)(ii)) shall be due on or before the expiration date of the contract.
          If no invention is disclosed or no activity has occurred on a previously disclosed invention during the applicable reporting period, a negative report shall be submitted to the Contracting Officer.


   

  		d.	Publications

          Any manuscript or scientific meeting abstract containing data generated under this contract must be submitted to COR for review prior to submission. Reports shall be due within 30 calendar days for manuscripts and 15 calendar days for abstracts.


   

  		e.	Press Releases

          The Contractor agrees to accurately and factually represent the work conducted under this contract in all press releases. The Contractor shall ensure the Contracting Officer has received and approved an advanced copy of any press release not less
          than two (2) business days prior to the issuance of any potential press release.


   

  		g.	Incident Security Report

          The Contractor shall report to the government any activity; or incident that is in violation of established security standards; or indicates the loss or theft of government products. Reports shall be due within 24 hours after occurrence of an
          activity or incident.


   

  		h.	Security Plan

          The Contractor shall submit a draft security plan within 90 days of contract award. A detailed security plan with any updates shall be submitted for approval at least three (3) months prior to the initiation of product procurement with proper
          documentation. The Contractor shall cooperate with USG representatives to develop a sustainable security plan to ensure continued security of the premises. Security plan updates are required when an incident security report has been filed.


   

  		i.	Quality Management System (QMS) Plan

          The Contractor shall provide a QMS plan within 90 days of contract award with updates at least three (3) months prior to initiation of product procurement or as directed by the COR or Co-COR. The Contractor agrees to incorporate USG feedback and
          address concerns relating to QMS plans.


   

  

  
  
    	16


  

  
    	 


  

  
   

  		j.	Quality Agreement Report

          The Quality Agreement Report shall specify the responsibilities of both the Contractor and the USG (i.e. – CDC/SNS-Quality Control and BARDA) for event-driven and product shipping, receiving, acceptance into the inventory and/or custody by the
          USG. These documents shall be drafted and signed by all parties prior to the commencement of product procurement and acceptance, transport and custody of the product under the VMI/DMI or the CDC/SNS. The Contractor shall provide documentation and
          resolution for all concerns raised by USG and commits to cooperation in execution of this agreement. Quality Agreement Reports are due at least three (3) months prior to initiation of product procurement or as directed by the COR or Co-COR.


   

  		k.	Vendor Managed Inventory (VMI) Plan

          The Contractor shall develop a plan to establish VMI in alignment with the Quality Agreement Report. Interim draft plans shall be submitted to USG as part of the development process. Draft submission for review is due upon completion of pre-EUA
          package. Final submission is required to initiate product procurement through a COA. Documents shall be updated as required by the COR or Co-COR. Developmental updates should be reported in the monthly reports as requested by the COR or Co-COR.


   

  A minimum of three (3) product deliveries from different manufacturing lots shall be delivered and accepted by USG to the inventory (considered as substantial delivery to the
    inventory) before the Contractor shall invoice for the product payment.

   

  		F.	Earned Value Management System Plan


   

  		a.	Earned Value Management System Plan:


   

  Subject to the requirements under HHSAR Clause 352.234-3, the Contractor shall use principles of Earned Value Management System (EVMS) in the management of this contract (include
    this plan as part of the monthly, annual, and final reports). The Seven Principles are:

   

  		I.	Plan all work scope for the program to completion.


   

  		II.	Break down the program work scope into finite pieces that can be assigned to a responsible person or organization for control of technical, schedule, and cost objectives.


   

  		III.	Integrate program work scope, schedule, and cost objectives into a performance measurement baseline plan against which accomplishments may be measured. Control changes to the baseline.


   

  		IV.	Use actual cost incurred and recorded in accomplishing the work performed.


   

  		V.	Objectively assess accomplishments at the work performance level.


   

  		VI.	Analyze significant variances from the plan, forecast impacts, and prepare an estimate at completion based on performance to date and work to be performed.


   

  		VII.	Use earned value information in the company’s management processes.


   

  

  
  
    	17


  

  
    	 


  

  
   

  		VIII.	Elements of EVMS shall be applied to all CLINs as part of the Integrated Master Project Plan, the Contractor shall submit a written summary of the management procedures that it will establish, maintain and use to comply with EVMS requirements.


   

  		b.	Performance Measurement Baseline Review (PMBR):


   

  The Contractor shall submit a PMBR plan electronically via email to the CO and COR for a PMBR to occur within 90 days of contract award. At the PMBR, the Contractor and BARDA
    shall mutually agree upon the budget, schedule and technical plan baselines (Performance Measurement Baseline). These baselines shall be the basis for monitoring and reporting progress throughout the life of the contract. The PMBR is conducted to
    achieve confidence that the baselines accurately capture the entire technical scope of work, are consistent with contract schedule requirements, are reasonably and logically planned, and have adequate resources assigned. The goals of the PMBR are
      as FOLLOWS:

   

  		I.	Jointly assess areas such as the Contractor’s planning for complete coverage of the SOW, logical scheduling of the work activities, adequate resources, and identification of inherent risks.


   

  		II.	Confirm the integrity of the Performance Measurement Baseline (PMB).


   

  		III.	Foster the use of EVM as a means of communication.


   

  		IV.	Provide confidence in the validity of Contractor reporting


   

  		V.	Identify risks associated with the PMB.


   

  		VI.	Present any revised PMBs for approval.


   

  		VII.	Present an Integrated Master Schedule: The Contractor shall deliver an initial program level Integrated Master Schedule (IMS) that rolls up all time-phased WBS elements down to the activity level. This IMS shall include the dependencies that
          exist between tasks. This IMS will be agreed to and finalized at the PMBR. DI-MGMT-81650 may be referenced as guidance in creation of the IMS (see http://www.acq.osd.mil/pm/).


   

  		VIII.	Present the Risk Management Plan.


   

  		c.	Integrated Master Schedule


   

  The Contractor shall submit an IMS electronically via email as outlined in a format agreed upon by BARDA to the COR and the Contracting Officer for approval prior to the
    initiation of any activities of sufficient size and cost to require EVMS. The Integrated Master Schedule shall be incorporated into the contract, and shall be used to monitor performance of the contract. The Contractor shall include the key milestones
    and Go/No Go decision gates. The Contractor shall include BARDA Portfolio Management Milestones (See the AMCG Business Toolkit for a description and sample (http://www.phe.gov/about/amcg/contracts/Pages/toolkit.aspx) in their IMS and provide
    monthly updates within their IMS. This IMS shall include the following fields at a minimum; baseline start and finish, forecast start and finish, actual start and finish, predecessor and/or successor. The Contractor shall deliver the Integrated Master
    Schedule, viewed at the work package level in MS Project file format

   

  

  
  
    	18


  

  
    	 


  

  
   

  		d.	Earned Value Contract Performance Report (EV-CPR)


   

  		a.	The Offeror shall deliver an Earned Value Contract Performance Report (CPR) on a monthly basis per the instruction in DI-MGMT-81466A (see http://www.acq.osd.mil/pm/). The Contractor shall provide Format 1, Format 3, and Format 5 only.
          Format 1 will be reported at the Work Breakdown Structure level agreed to by BARDA and the Contractor.


   

  		b.	EV Variance thresholds will be negotiated with the Contractor post-award but for planning purposes will likely be (+/- 10%). In conjunction with the CPR, the Contractor shall provide a monthly update to the IMS with up to date performance data
          and shall include actual start/finish and projected start / finish dates.


   

  		c.	The supplemental monthly CAP report shall contain, at the work package level, time phased budget (budgeted cost of work scheduled (BCWS)), earned value (budgeted cost of work performed (BCWP)), and actual costs of work performed (ACWP) as
          captured in the Contractor’s EVM systems.


   

  		d.	The Contractor and BARDA shall participate in regular meetings to coordinate and oversee the contracting effort as requested by the COR. Such meetings may include, but are not limited to, site visits to the Contractor’s and/or subcontractor’s
          facilities, meetings with individual Contractors and other HHS officials to discuss the technical, regulatory, and ethical aspects of the program. The Contractor shall provide data, reports, and presentations to groups of outside experts and USG
          personnel and Government-contracted subject matter experts as required by the BARDA COR in order to facilitate review of contract activities.


   

  		e.	The Contractor shall provide a list of individuals to serve as primary and secondary points of contact who will be available 24 hours a day, seven days a week, to be notified in case of a public health emergency.


   

  

  
  
    	19


  

  
    	 


  

  
   

  ARTICLE F.3.   DELIVERIES

   

  Successful performance of the final contract shall be deemed to occur upon performance of the work set forth in the Statement of Work dated September 28, 2015 set forth in SECTION J -
    List of Attachments of this contract and upon delivery and acceptance by the Contracting Officer, or the duly authorized representative, of the following items in accordance with the stated delivery schedule below:

   

  	Item 

            No.	Description	Addresses	Deliverable Schedule
	1	Monthly Progress Report	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Reports are due on or before the 15th of each month following the end of each reporting period.
	2	Annual Progress Report	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Reports are due on or before the 30th calendar day following the end of each reporting period.
	3	Draft Final Progress Report	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Report is due 45 Calendar days prior to the expiration date of the contract.
	4	Final Progress Report	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Report is due no later than 30 calendar days after the expiration date of the contract.
	5	
          FDA/ Regulatory Agency 

          Correspondence and Meeting Summaries

           

        	COR: (1) electronic copy	Reports are due within 5 business days of each meeting for Contractor’s minutes, upon receipt of minutes from FDA/ regulatory
          agency, and upon request from the COR or Co-COR.
	6	
          Integrated Master Project Plan

            -Critical Path Milestones 

          - Work Breakdown Structure 

          - Risk Mitigation Plan/Matrix

           

        	COR: (1) electronic copy	Report is due within 90 days of contract award. Updates are due as requested by the COR or Alternate COR.
	7	Technology Packages	COR: (1) electronic copy	Upon request from the COR or Co-COR.
	8	Experimental Protocols	COR: (1) electronic copy	Upon request from the COR or Co-COR.
	9	Annual/Final Invention Report	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	An Annual Invention Report is due on or before the 30th calendar day after the completion of each reporting period. A
          Final Invention Report is due on or before the expiration date of the contract.
	10	Publications	COR: (1) electronic copy	Reports are due within 30 calendar days for manuscripts and 15 calendar days for abstracts.
	11	Press Releases	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Reports/Notices are due for approval to the CO not less than two (2) business days prior to the issuance of any potential press
          release.
	12	Incident Security Report	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Reports are due within 24 hours after occurrence of an activity or incident.
	13	Security Plan	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Draft report is due within 90 days of contract award. Updates are due at least 3 months prior to product procurement or as
          requested by the COR or Co-COR.
	14	Quality Management System (QMS) Plan	COR: (1) electronic copy	Draft report is due within 90 days of contract award. Updates are due at least 3 months prior to product procurement or as
          requested by the COR or Co-COR.
	15	Quality Agreement Report	COR: (1) electronic copy	Reports are due at least 3 months prior to product procurement or as directed by the COR or Co-COR.
	16	VMI Plan	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	Plan is due upon completion of the Pre-EAU package.
	17	Earned Value Management Requirements	
          CO: (1) electronic copy

           

          COR: (1) electronic copy

           

        	As detailed in Section F.2 Reporting Requirements, subpart -F.


    

  Email Addresses: CO – matthew.rose@hhs.gov

    COR – Julio.Barrera-Oro@hhs.gov

   

  

  
  
    	20


  

  
    	 


  

  
   

  ARTICLE F.4.   FEDERAL ACQUISITION REGULATION CLAUSES INCORPORATED BY REFERENCE, FAR 52.252-2 (FEBRUARY 1998)

   

  This contract incorporates the following clause(s) by reference, with the same force and effect as if it were given in full text. Upon request, the Contracting Officer will make its full
    text available. The full text of each clause may be accessed electronically at this address: http://www.acquisition.gov/comp/far/index.html.

   

  FAR 52.242-15, Stop Work Order (August 1989) 

  FAR 52.242-15, Stop Work Order (August 1989), Alternate 1 (April 1984)

   

  

  
  
    	21


  

  
    	 


  

  
   

   

   

  

  

  SECTION G – CONTRACT ADMINISTRATION DATA

  

   

  ARTICLE G.1.     CONTRACTING OFFICER

  

   

  The following Contracting Officer (CO) will represent the Government for the purpose
      of this contract: 

   

  Matthew Rose, CO

      DHHS/OS/ASPR/AMCG

      200 C St.

      Washington, D.C. 20024

  		a.	The Contracting Officer (CO) is the only individual who can legally commit the Government to the expenditure of public funds. No person other than the CO can make
            any changes to the terms, conditions, general provisions, specifications or other requirements of this contract.


  		b.	The Contracting Officer (CO) is the only person with authority to act as agent of the Government under this contract. Only the CO has authority to: (1) direct or
            negotiate any changes in the statement of work; (2) modify or extend the period of performance; (3) change the delivery schedule; (4) authorize reimbursement to the Contractor for any costs incurred during the performance of this contract; or
            (5) otherwise change any terms and conditions of this contract.


  		c.	No information, other than that which may be contained in an authorized modification to this contract duly issued by the CO, shall be considered grounds for
            deviation from this contract.


  

  		d.	The Government may unilaterally change its CO designation


   

  ARTICLE G.2.    CONTRACTING OFFICER’S REPRESENTATIVE (COR)

   

  

  The following Contracting Officer’s Representative (COR) will represent the Government for
      the purpose of this contract: 

   

  Julio Barrera-Oro, PhD 

      Contracting Officer’s Representative

  Biomedical Advanced Research and Development Authority (BARDA) 

      Office of the Assistant Secretary for Preparedness and Response 

      Department of Health and Human Services 

      Julio.Barrera-Oro@hhs.gov 

      (202) 260-0393

  

   

  Mailing Address:

  330 Independence Avenue, S.W. 

      Room 640G

  Washington, D.C. 20201 

   

  Alternate COR:

   

  Narayan Iyer, PhD

  Alternate Project Officer (PO), Alternate Contracting Officer’s Representative (COR)

  Biomedical Advanced Research and Development Authority (BARDA)

  Office of the Assistant Secretary for Preparedness and Response

  Department of Health and Human Services

  narayan.iyer@hhs.gov

  (202) 260-0455

   

  

  
  
    	22 


  

  
    	 


  

  
    

  Mailing Address:

  330 Independence Avenue, SW, RM G-640 

      Washington, D.C. 20201

   

  The COR is responsible for:

  		a.	Monitoring the Contractor’s technical progress, including the surveillance and assessment of performance and recommending to the Contracting Officer changes in
            requirements;


  		b.	Assisting the Contracting Officer in interpreting the statement of work and any other technical performance requirements;


  		c.	Performing technical evaluation as required;


  		d.	Performing technical inspections and assisting the Contracting Officer in acceptances of deliverables required by this contract; and


  		e.	Assisting in the resolution of technical problems encountered during performance.


  		f.	The Government may unilaterally change its COR designation(s).


   

  ARTICLE G.3.     KEY PERSONNEL

   

  The key personnel specified in this contract are considered to be essential to work
      performance. At least 30 days prior to diverting any of the specified individuals to other programs or contracts (or as soon as possible, if an individual must be replaced, for example, as a result of leaving the employ of the Contractor), the
      Contractor shall notify the Contracting Officer and shall submit comprehensive justification for the diversion or replacement request (including proposed substitutions for key personnel) to permit evaluation by the Government of the impact on
      performance under this contract. The Contractor shall not divert or otherwise replace any key personnel without the written consent of the Contracting Officer. The Government may modify the contract to add or delete key personnel at the request of
      the Contractor or Government.

   

  The following individuals are considered to be essential to the work being performed
      hereunder:

   

  

  	Name	Title
	Gal Cohen	President and CEO
	Dr. Lior Rosenberg	Chief Medical Officer
	Dr. Ety Klinger	Chief R&D Officer
	Andrey Kon	Plant Manager
	Dr. Eilon Asculai	VP R&D
	Smadar Nestor	Director Regulatory Affairs
	Nimrod Leuw	Director of QA/QC
	Keren David-Zabriv	Director Clinical Affairs


  

  	


   

  ARTICLE G.4.     INVOICE SUBMISSION

  		a.	The Contractor shall submit an electronic copy of contract monthly invoices/financial reports to the Contracting Officer as defined above, in ARTICLE G of this
            contract.


  		b.	Contractor invoices/financial reports shall conform to the form, format, and content requirements of the instructions for Invoice/Financing requests made a part of
            the contract at Section J, Attachments 2 & 3.


  		c.	Monthly invoices must include the cumulative total expenses to date, adjusted (as applicable) to show any amounts suspended by the Government.


  		d.	The Contractor agrees to immediately notify the Contracting Officer in writing if there is an anticipated overrun (any amount) or unexpended balance (greater than
            10 percent) of the estimated costs for the base period or any options for additional quantities (See estimated costs under Articles B.2 and B.3) and the reasons for the variance. Also
              refer to the requirements of FAR Clause 52.232-20, Limitation of Cost.


  

   

  

  
  
    	23 


  

  
    	 


  

  
   

  		e.	The Contractor shall submit an electronic copy of the payment request to the approving official instead of a paper copy. The payment request shall be transmitted as
            an attachment via e-mail to the address listed above in one of the following formats: MSWord, MS Excel, or Adobe Portable Document Format (PDF). Only one payment request shall be submitted per e-mail and the subject line of the e-mail shall
            include the Contractor’s name, contract number, and unique invoice number.


  		f.	All invoice submissions shall be in accordance with FAR Clause 52.232-25, Prompt Payment.


   

  ARTICLE G.5.     INDIRECT COST RATES

  		1.	The following interim provisional indirect rates will be utilized for billing purposes during the period of performance: 80%. Final rate proposals must be
            sent to the Contracting Officer, within 6 months of the fiscal year end. See FAR Clause 52.216-7, Allowable Cost and Payment.


  		2.	The interim provisional indirect rates used in this contract have been established after approval by the AMCG/BARDA Auditor.


   

  ARTICLE G.6.      REIMBURSEMENT OF COST

   

  		1)	The Government shall reimburse the Contractor those costs determined by the Contracting Officer to be allowable (hereinafter referred to as allowable cost) in accordance with FAR 52.216-7,
            Allowable Cost and Payment and FAR Subpart 31.2. Examples of allowable costs include, but are not limited to, the following:


  		a)	All direct materials and supplies that are used in the performing of the work provided for under the contract, including those purchased for subcontracts and
            purchase orders.


  		b)	All direct labor, including supervisory, that is properly chargeable directly to the contract, plus fringe benefits.


  		c)	All other items of cost budgeted for and accepted in the negotiation of this basic contract or modifications thereto.


  		d)	Travel costs including per diem or actual subsistence for personnel while in an actual travel status in direct performance of the work and services required under
            this contract subject to the following:


  		i.	Air travel shall be by the most direct route using “air coach” or “air tourist” (less than first class) unless it is clearly unreasonable or impractical (e.g., not
            available for reasons other than avoidable delay in making reservations, would require circuitous routing or entail additional expense offsetting the savings on fare, or would not make necessary connections).


  		ii.	Rail travel shall be by the most direct route, first class with lower berth or nearest equivalent.


  		iii.	Costs incurred for lodging, meals, and incidental expenses shall be considered reasonable and allowable to the extent that they do not exceed on a daily basis
            the per diem rates set forth in the Federal Travel Regulation (FTR).


  		iv.	Travel via privately owned automobile shall be reimbursed at not more than the current General Services Administration (GSA) FTR established mileage rate.
	 	 	 


  

  
  
    	24 


  

  
    	 


  

  
   

  

   

  ARTICLE G.7.     POST AWARD EVALUATION OF CONTRACTOR PERFORMANCE

   

  1. Contractor Performance Evaluations

   

  Interim and final evaluations of Contractor performance will be prepared on this contract in accordance with FAR Subpart
      42.15. The final performance evaluation will be prepared at the time of completion of work. In addition to the final evaluation, interim evaluation(s) will be prepared annually as to coincide with the Anniversary date of the contract.

   

  Interim and final evaluations will be provided to the Contractor as soon as practicable after completion of the
      evaluation. The Contractor will be permitted thirty days to review the document and to submit additional information or a rebutting statement. If agreement cannot be reached between the parties, the matter will be referred to an individual one level
      above the Contracting Officer whose decision will be final.

   

  Copies of the evaluations, Contractor responses, and review comments, if any, will be retained as part of the contract
      file, and may be used to support future award decisions.

   

  2. Electronic Access to Contractor Performance Evaluations

   

  Contractors may access evaluations through a secure website for review and comment at the following:

   

  http://cpars.gov

   

  ARTICLE G.8.     CONTRACT COMMUNICATIONS/CORRESPONDENCE (JULY 1999)

   

  The Contractor shall identify all correspondence, reports, and other data pertinent to this contract by imprinting the contract
      number HHSO100201500035C from Page 1 of the contract

   

  ARTICLE G.9.     GOVERNMENT PROPERTY

   

  		1.	In addition to the requirements of the clause, GOVERNMENT PROPERTY, incorporated in SECTION I of this contract, the Contractor shall comply with the provisions of HHS Publication,
            “Contractor’s Guide for Control of Government Property,” which is incorporated into this contract by reference. This document can be accessed at:


   

  http://www.hhs.gov/hhsmanuals/               (HHS Logistics Management Manual)

   

  Among other issues, this publication provides a summary of the Contractor’s responsibilities regarding purchasing
      authorizations and inventory and reporting requirements under the contract.

   

  		2.	Notwithstanding the provisions outlined in the HHS Publication, “Contractor’s Guide for Control of Government Property,” which is incorporated in this contract in paragraph 1. above, the
            Contractor shall use the form entitled, “Report of Government Owned, Contractor Held Property” for submitting summary reports required under this contract, as directed by the Contracting Officer or his/her designee. This form is included as an
            attachment in SECTION J of this contract.


   

  		3.	Title will vest in the Government for equipment purchased as a direct cost.


   

  
  
    	25


  

  
    	 


  

  
  

   

  SECTION H – SPECIAL CONTRACT REQUIREMENTS

   

  ARTICLE H.1.     PROTECTION OF HUMAN SUBJECTS, HHSAR 352.270-4(b) (January 2006)

   

  		a.	The Contractor agrees that the rights and welfare of human subjects involved in research under this contract shall be protected in accordance with 45 CFR Part 46 and with the Contractor’s
            current Assurance of Compliance on file with the Office for Human Research Protections (OHRP), Department of Health and Human Services. The Contractor further agrees to provide certification at least annually that the Institutional Review Board
            has reviewed and approved the procedures, which involve human subjects in accordance with 45 CFR Part 46 and the Assurance of Compliance.


   

  		b.	The Contractor shall bear full responsibility for the performance of all work and services involving the use of human subjects under this contract and shall ensure that work is conducted in
            a proper manner and as safely as is feasible. The parties hereto agree that the Contractor retains the right to control and direct the performance of all work under this contract. The Contractor shall not deem anything in this contract to
            constitute the Contractor or any subcontractor, agent or employee of the Contractor, or any other person, organization, institution, or group of any kind whatsoever, as the agent or employee of the Government. The Contractor agrees that it has
            entered into this contract and will discharge its obligations, duties, and undertakings and the work pursuant thereto, whether requiring professional judgment or otherwise, as an independent contractor without imputing liability on the part of
            the Government for the acts of the Contractor or its employees.


   

  		c.	If at any time during the performance of this contract, the Contracting Officer determines, in consultation with OHRP that the Contractor is not in compliance with any of the requirements
            and/or standards stated in paragraphs (a) and (b) above, the Contracting Officer may immediately suspend, in whole or in part, work and further payments under this contract until the Contractor corrects the noncompliance. The Contracting
            Officer may communicate the notice of suspension by telephone with confirmation in writing. If the Contractor fails to complete corrective action within the period of time designated in the Contracting Officer’s written notice of suspension,
            the Contracting Officer may, after consultation with OHRP, terminate this contract in whole or in part, and the Contractor’s name may be removed from the list of those contractors with approved Human Subject Assurances.


   

  ARTICLE H.2.     CLINICAL RESEARCH

   

  These Clinical Terms apply to all contracts that involve clinical research.

   

  The Government shall have unlimited rights to all protocols, data generated from the execution of these
      protocols, and final reports, funded by the Government under this contract, as defined in Rights in Data Clause in FAR 52.227-14. The Government reserves the right to request that the Contractor provide any contract deliverable in a non-proprietary
      form, to ensure the Government has the ability to review and distribute the deliverables, as the Government deems necessary.

   

  H.2.1     Safety and Monitoring Issues

   

  Institutional Review Board (IRB) or Independent Ethics Committee (IEC) Approval

   

  Before award and then with Annual Progress Reports, the Contractor shall submit to the Government a copy of the current IRB or IEC
      approved informed consent document, documentation of continuing review and approval and the Office of Human Research Protections (OHRP) FWA number for the institution or site.

   

  If other institutions are involved in the research (e.g., a multicenter clinical trial or study), each institution’s IRB or IEC must
      review and approve the protocol. They must also provide the Government initial and annual documentation of continuing review and approval, including the current approved informed consent document and FWA number.

   

  

  
  
    	26


  

  
    	 


  

  
   

  The grantee institution must ensure that the applications as well as all protocols are reviewed by their IRB or IEC.

   

  To help ensure the safety of participants enrolled in BARDA-funded studies, the Contractor must provide the Government a summary
      explanation and copies of documents related to all major changes in the status of ongoing protocols, including the following:

   

  

  	 	1.	All amendments or changes to the protocol, identified by protocol version number, date, or both and date it is valid.
	 	2.	All changes in informed consent documents, identified by version number, date, or both and dates it is valid.
	 	3.	Termination or temporary suspension of patient accrual.
	 	4.	Termination or temporary suspension of the protocol.
	 	5.	Any change in IRB approval.
	 	6.	Any other problems or issues that could affect the participants in the studies.


    

  Contractors must notify BARDA through the Contracting Officer’s Technical Representative (COR) and Contracting
      Officer (CO) of any of the above changes within 24 hours by email, followed by a letter signed by the institutional business official, detailing notification of the change of status to the local IRB and a copy of any responses from the IRB or IEC.

   

  If a clinical protocol has been reviewed by an Institutional Bio-safety Committee (IBC) or the NIH Recombinant
      DNA Advisory Committee (RAC), the Contractor must provide information about the initial and ongoing review and approval, if any. See the NIH Guidelines for Research Involving Recombinant DNA Molecules.

   

  H.2.2.     Data and Safety Monitoring Requirements

   

  The Contractor may be required to conduct independent safety monitoring for clinical trials of investigational drugs, devices, or
      biologics; clinical trials of licensed products; and clinical research of any type involving more than minimal risk to volunteers. Independent monitoring can take a variety of forms. Phase III clinical trials must have an assigned independent data
      and safety monitoring board (DSMB); other trials may require DSMB oversight as well. The Contractor shall inform the Government of any upcoming site visits and/or audits of Contractor facilities funded under this effort. BARDA reserves the right to
      accompany the Contractor on site visits and/or audits of Contractors and Subcontractors as the Government deems necessary.

   

  The type of monitoring to be used shall be mutually agreed upon between the Contractor and the Government before enrollment starts.
      Discussions with the responsible BARDA COR regarding appropriate safety monitoring and approval of the final monitoring plan by BARDA must occur before patient enrollment begins and may include discussions about the appointment of one of the
      following:

   

  	 	1.	Independent Safety Monitor – a physician or other appropriate expert who is independent of the study and available in
            real time to review and recommend appropriate action regarding adverse events and other safety issues.
	 	2.	Independent Monitoring Committee (IMC) or Safety Monitoring Committee (SMC) – a small group of independent investigators and
            biostatisticians who review data from a particular study.
	 	3.	Data and Safety Monitoring Board – an independent committee charged with reviewing safety and trial progress and providing advice with respect to study
            continuation, modification, and termination. The Contractor may be required to use an established BARDA DSMB or to organize an independent DSMB. All phase III clinical trials must be reviewed by a DSMB; other trials may require DSMB oversight
            as well. Please refer to: NIAID Principles for Use of a Data and Safety Monitoring Board (DSMB) For Oversight of Clinical Trials Policy. The Government retains the right to place a nonvoting member on the DSMB.


   

  

  
  
    	27


  

  
    	 


  

  
   

  When a monitor or monitoring board is organized, a description of it, its charter or operating procedures
      (including a proposed meeting schedule and plan for review of adverse events), and roster and curriculum vitae from all members must be submitted to and approved by the Government before enrollment starts.

   

  Additionally, the Contractor must submit written summaries of all reviews conducted by the monitoring group to
      the Government within 30 days of reviews or meetings.

   

  H.2.3.     BARDA Protocol Review Process Before Patient Enrollment Begins

   

  BARDA has a responsibility to ensure that mechanisms and procedures are in place to protect the safety of
      participants in BARDA-supported clinical trials. Therefore, before patient accrual or participant enrollment, the Contractor must provide the following (as applicable) for review and approval by the Government:

   

  	 	1.	IRB or IEC approved clinical research protocol identified by version number, date, or both, including details of study design, proposed
            interventions, patient eligibility, and exclusion criteria;
	 	2.	Documentation of IRB or IEC approval, including OHRP FWA number, IRB or IEC registration number, and IRB or IEC name;
	 	3.	IRB or IEC approved informed consent document, identified by version number, date, or both and date it is valid;
	 	4.	Plans for the management of side effects;
	 	5.	Procedures for assessing and reporting adverse events;
	 	6.	Plans for data and safety monitoring (see B above) and monitoring of the clinical study site, pharmacy, and laboratory;
	 	7.	Documentation that the Contractor and all study staff responsible for the design or conduct of the research have received Good Clinical Practice (GCP) training
            in the protection of human subjects.


   

  BARDA comments will be forwarded to the Contractor within two weeks (10 business days) of receipt of the above
      information. The Contractor must address in writing all study design, safety, regulatory, ethical, and conflict of interest concerns raised by the BARDA COR to the satisfaction of the Government before patient accrual or participant enrollment can
      begin. After the Government receives the corrected documentation, a written protocol approval will be provided by the COR to the Contractor. This written approval provides authorization to the Contractor to execute the specific clinical study funded
      in part or in whole by the Government.

   

  Documentation of IRB or IEC approval, including OHRP FWA number, IRB or IEC registration number, and IRB and IEC
      name, must be provided to the BARA COR within 24 hours of receipt by the Contractor.

   

  H.2.4.     Required Time-Sensitive Notification

   

  Under an IND or IDE, the sponsor must provide FDA safety reports of serious adverse events. Under these Clinical
      Terms of Award, the Contractor must submit copies to the responsible Contracting Officer’s representative (COR) as follows:

   

  	 	1.	Expedited safety report of unexpected or life-threatening experience or death – A copy of any report of unexpected or life-threatening
            experience or death associated with the use of an IND drug, which must be reported to FDA by telephone or fax as soon as possible but no later than seven days after the IND sponsor’s receipt of the information, must be submitted to the
            Contracting Officer’s Representative within 24 hours of FDA notification.


   

  
  
    	28


  

  
    	 


  

  
  

  

  

   

  		2.	Expedited safety reports of serious and unexpected adverse experiences – A copy of any report of unexpected and serious adverse experience associated with use of an IND drug or any finding from tests in
          laboratory animals that suggests a significant risk for human subjects, which must be reported in writing to FDA as soon as possible but no later than 15 calendar days after the IND sponsor’s receipt of the information, must be submitted to the
          Contracting Officer’s Representative within 24 hours of FDA notification.


   

  		3.	IDE reports of unanticipated adverse device effect – A copy of any reports of unanticipated adverse device effect submitted to FDA must be submitted to the Contracting Officer’s Representative within 24 hours
          of FDA notification.


   

  		4.	Expedited safety reports – shall be sent to the COR concurrently with the report to FDA.


   

  		5.	Other adverse events documented during the course of the trial shall be included in the annual IND or IDE report and reported to the BARDA annually.


   

  In case of problems or issues, the COR will contact the Contractor within 10 working days by email, followed within 7 calendar days by an official letter to the
    Contractor. The Contractor shall forward the official letter to the principal investigator listing issues and appropriate actions to be discussed.

   

  Safety reporting for research not performed under an IND or IDE

   

  Ongoing safety reporting requirements for research not performed under an IND or IDE shall be mutually agreed upon by the Contracting Officer’s Representative and the
    Contractor.

   

  	ARTICLE H.3.	HUMAN MATERIALS


   

  The acquisition and supply of all human specimen material (including fetal material) used under this contract shall be obtained by the Contractor in full compliance with applicable State
    and Local laws and the provisions of the Uniform Anatomical Gift Act in the United States, and no undue inducements, monetary or otherwise, will be offered to any person to influence their donation of human material.

   

  	ARTICLE H.4. 	CARE OF LIVE VERTEBRATE ANIMALS


   

  		a.	Before undertaking performance of any contract involving animal-related activities where the species is regulated by USDA, the Contractor shall register with the Secretary of Agriculture of the United States in accordance with 7 U.S.C. 2136 and
          9 CFR sections 2.25 through 2.28. The Contractor shall furnish evidence of the registration to the Contracting Officer.


   

  		b.	The Contractor shall acquire vertebrate animals used in research from a dealer licensed by the Secretary of Agriculture under 7 U.S.C. 2133 and 9 CFR Sections 2.1-2.11, or from a source that is exempt from licensing under those sections.


   

  		c.	The Contractor agrees that the care, use and intended use of any live vertebrate animals in the performance of this contract shall conform with the Public Health Service (PHS) Policy on Humane Care of Use of Laboratory Animals (PHS Policy), the
          current Animal Welfare Assurance (Assurance), the Guide for the Care and Use of Laboratory Animals (National Academy Press, Washington, DC) and the pertinent laws and regulations of the United States Department of Agriculture (see 7 U.S.C. 2131
          et seq. and 9 CFR Subchapter A, Parts 1-4). In case of conflict between standards, the more stringent standard shall govern.


   

  		d.	If at any time during performance of this contract, the Contracting Officer determines, in consultation with the Office of Laboratory Animal Welfare (OLAW), National Institutes of Health (NIH), that the Contractor is not in compliance with any
          of the requirements and standards stated in paragraphs (a) through (c) above, the Contracting Officer may immediately suspend, in whole or in part, work and further payments under this contract until the Contractor corrects the noncompliance.
          Notice of the suspension may be communicated by telephone and confirmed in writing. If the Contractor fails to complete corrective action within the period of time designated in the Contracting Officer’s written notice of suspension, the
          Contracting Officer may, in consultation with OLAW, NIH, terminate this contract in whole or in part, and the Contractor’s name may be removed from the list of those contractors with approved Assurances.


   

  

  
  
    	29


  

  
    	 


  

  
   

  Note: The Contractor may request registration of its facility and a current listing of licensed dealers from the Regional Office of
      the Animal and Plant Health Inspection Service (APHIS), USDA, for the region in which its research facility is located. The location of the appropriate APHIS Regional Office, as well as information concerning this program may be obtained by
      contacting the Animal Care Staff, USDA/APHIS, 4700 River Road, Riverdale, Maryland 20737 (E-mail: ace@aphis.usda.gov; Web site: (http://www.aphis.usda.gov/animal welfare).

   

  	ARTICLE H.5.	ANIMAL WELFARE


   

  All research involving live, vertebrate animals shall be conducted in accordance with the Public Health Service Policy on Humane
      Care and Use of Laboratory Animals. This policy may be accessed at:http://grants1.nih.gov/grants/olaw/references/phspol.htm

   

  	ARTICLE H.6.	INFORMATION ON COMPLIANCE WITH ANIMAL CARE REQUIREMENTS


   

  Registration with the U. S. Dept. of Agriculture (USDA) is required to use regulated species of animals for biomedical purposes.
      USDA is responsible for the enforcement of the Animal Welfare Act (7 U.S.C. 2131 et. seq.), http://www.nal.usda.gov/awic/legislat/awa.htm.

   

  The Public Health Service (PHS) Policy is administered by the Office of Laboratory Animal Welfare (OLAW) http://grants2.nih.gov/grants/olaw/olaw.htm.
    An essential requirement of the PHS Policy http://grants2.nih.gov/grants/olaw/references/phspol.htm is that every institution using live vertebrate animals must obtain an approved assurance from OLAW before they can receive funding from any
    component of the U. S. Public Health Service.

   

  The PHS Policy requires that Assured institutions base their programs of animal care and use on the Guide for the Care and Use of
      Laboratory Animals http://www.nap.edu/readingroom/books/labrats/ and that they comply with the regulations (9 CFR, Subchapter A) http://www.nal.usda.gov/awic/legislat/usdaleg1.htm issued by the U.S. Department of Agriculture
    (USDA) under the Animal Welfare Act. The Guide may differ from USDA regulations in some respects. Compliance with the USDA regulations is an absolute requirement of this Policy.

   

  The Association for Assessment and Accreditation of Laboratory Animal Care International (AAALAC) http://www.aaalac.org
    is a professional organization that inspects and evaluates programs of animal care for institutions at their request. Those that meet the high standards are given the accredited status. As of the 2002 revision of the PHS Policy, the only accrediting
    body recognized by PHS is the AAALAC. While AAALAC Accreditation is not required to conduct biomedical research, it is highly desirable. AAALAC uses the Guide as their primary evaluation tool. They also use the Guide for the Care and Use of
    Agricultural Animals in Agricultural Research and Teaching. It is published by the Federated of Animal Science Societies http://www.fass.org.

   

  	ARTICLE H.7.	REQUIREMENTS FOR ADEQUATE ASSURANCE OF PROTECTION OF VERTEBRATE ANIMAL SUBJECTS


   

  The PHS Policy on Humane Care and Use of Laboratory Animals requires that applicant organizations proposing to use vertebrate
      animals file a written Animal Welfare Assurance with the Office for Laboratory Animal Welfare (OLAW), establishing appropriate policies and procedures to ensure the humane care and use of live vertebrate animals involved in research activities
      supported by the PHS. The PHS Policy stipulates that an applicant organization, whether domestic or foreign, bears responsibility for the humane care and use of animals in PHS- supported research activities. Also, the PHS policy defines “animal” as
      “any live, vertebrate animal used, or intended for use, in research, research training, experimentation, biological testing or for related purposes.” This Policy implements and supplements the U.S. Government Principles for the Utilization and Care
      of Vertebrate Animals Used in Testing, Research, and Training, and requires that institutions use the Guide for the Care and Use of Laboratory Animals as a basis for developing and implementing an institutional animal care and use program.
    This Policy does not affect applicable State or local laws or regulations that impose more stringent standards for the care and use of laboratory animals. All institutions are required to comply, as applicable, with the Animal Welfare Act as amended (7
    USC 2131 et. seq.) and other Federal statutes and regulations relating to animals. These documents are available from the Office of Laboratory Animal Welfare, National Institutes of Health, Bethesda, MD 20892, (301) 496-7163. See http://grants.nih.gov/grants/olaw/olaw.htm.

   

  

  
  
    	30


  

  
    	 


  

  
   

  No PHS supported work for research involving vertebrate animals will be conducted by an organization, unless that organization is operating in accordance with an approved Animal Welfare
    Assurance and provides verification that the Institutional Animal Care and Use Committee (IACUC) has reviewed and approved the proposed activity in accordance with the PHS policy. Applications may be referred by the PHS back to the institution for
    further review in the case of apparent or potential violations of the PHS Policy. No award to an individual will be made unless that individual is affiliated with an assured organization that accepts responsibility for compliance with the PHS Policy.
    Foreign applicant organizations applying for PHS awards for activities involving vertebrate animals are required to comply with PHS Policy or provide evidence that acceptable standards for the humane care and use of animals will be met. Foreign
    applicant organizations are not required to submit IACUC approval, but should provide information that is satisfactory to the Government to provide assurances for the humane care of such animals.

   

  	ARTICLE H.8.	APPROVAL OF REQUIRED ASSURANCE BY OLAW


   

  Under governing regulations, federal funds which are administered by the Department of Health and Human Services, Office of Biomedical Advanced Research and Development Authority (BARDA)
    shall not be expended by the Contractor for research involving live vertebrate animals, nor shall live vertebrate animals be involved in research activities by the Contractor under this award unless a satisfactory assurance of compliance with 7 U.S.C.
    2316 and 9 CFR Sections 2.25-2.28 is submitted within 30 days of the date of this award and approved by the Office of Laboratory Animal Welfare (OLAW). Each performance site (if any) must also assure compliance with 7 U.S.C. 2316 and 9 CFR Sections
    2.25-2.28 with the following restriction: Only activities which do not directly involve live vertebrate animals (i.e. are clearly severable and independent from those activities that do involve live vertebrate animals) may be conducted by the
    Contractor or individual performance sites pending OLAW approval of their respective assurance of compliance with 7 U.S.C. 2316 and 9 CFR Sections 2.25-2.28. Additional information regarding OLAW may be obtained via the Internet at http://grants2.nih.gov/grants/olaw/references/phspol.htm

   

  	ARTICLE H.9.	NEEDLE DISTRIBUTION


   

  The Contractor shall not use contract funds to carry out any program of distributing sterile needles or syringes for the hypodermic injection of any illegal drug.

   

  	ARTICLE H.10.	ACKNOWLEDGEMENT OF FEDERAL FUNDING


   

  The Contractor shall clearly state, when issuing statements, press releases, requests for proposals, bid solicitations and other documents describing projects or programs funded in whole
    or in part with Federal money: (1) the percentage of the total costs of the program or project which will be financed with Federal money; (2) the dollar amount of Federal funds for the project or program; and (3) the percentage and dollar amount of the
    total costs of the project or program that will be financed by nongovernmental sources.

   

  	ARTICLE H.11.	RESTRICTION ON ABORTIONS


   

  The Contractor shall not use funds for any abortion.

   

  

  
  
    	31


  

  
    	 


  

  
   

  	ARTICLE H.12.	CONTINUED BAN ON FUNDING OF HUMAN EMBRYO RESEARCH


   

  The Contractor shall not use contract funds for (1) the creation of a human embryo or embryos for research purposes; or (2) research in which a human embryo or
    embryos are destroyed, discarded, or knowingly subjected to risk of Injury or death greater than that allowed for research on fetuses in utero under 45 CFR 46.204(b) and Section 498(b) of the Public Health Service Act (42 U.S.C. 289g(b)). The term
    “human embryo or embryos” includes any organism, not protected as a human subject under 45 CFR 46 as of the date of the enactment of this Act, that is derived by fertilization, parthenogenesis, cloning, or any other means from one or more human gametes
    or human diploid cells.

   

  Additionally, in accordance with the March 4, 1997 Presidential Memorandum entitled “Prohibition on Federal Funding for Cloning of Human Beings”, federal funds may not be used for cloning
    of human beings.

   

  	ARTICLE H.13.	DISSEMINATION OF FALSE OR DELIBERATELY MISLEADING INFORMATION


   

  The Contractor shall not use contract funds to disseminate information that is deliberately false or misleading.

   

  	ARTICLE H.14.	OMB CLEARANCE


   

  In accordance with HHSAR 352.201-70, Paperwork Reduction Act of 1980, (44 U.S.C. section 3501) the Contractor shall not proceed with surveys or interviews until such time as Office of
    Management and Budget (OMB) Clearance for conducting interviews has been obtained by the Contracting Officer’s Representative (COR) and the Contracting Officer has issued written approval to proceed.

   

  	ARTICLE H.15.	RESEARCH INVOLVING HUMAN FETAL TISSUE


   

  All research involving human fetal tissue shall be conducted in accordance with the Public Health Service Act, 42 U.S.C. 289g-1 and
      289g-2. Implementing regulations and guidance for conducting research on human fetal tissue may be found at 45 CFR 46, Subpart B and http://grants1.nih.gov/grants/guide/notice- files/not93-235.html and any subsequent revisions to this
    NIH Guide to Grants and Contracts (“Guide”) Notice.

   

  The Contractor shall make available, for audit by the Secretary, HHS, the physician statements and informed consents required by 42 USC 289g-1 (b) and (c), or ensure HHS access to those
    records, if maintained by an entity other than the Contractor.

   

  	ARTICLE H.16.	REPORTING MATTERS INVOLVING FRAUD, WASTE, AND ABUSE


   

  Anyone who becomes aware of the existence or apparent existence of fraud, waste and abuse in BARDA funded programs is encouraged to
      report such matters to the HHS Inspector General’s Office in writing or on the Inspector General’s Hotline. The toll free number is 1-800-HHS-TIPS (1-800-447-8477). All telephone calls will be handled confidentially. The e-mail address
    is Htips@os.dhhs.gov and the mailing address is:

   

  Office of Inspector General

  Department of Health and Human Services

  TIPS HOTLINE

  P.O. Box 23489

  Washington, D.C. 20026

   

  

  
  
    	32


  

  
    	 


  

  
   

  	ARTICLE H.17.	PROHIBITION ON CONTRACTOR INVOLVEMENT WITH TERRORIST ACTIVITIES


   

  The Contractor acknowledges that U.S. Executive Orders and Laws, including but not limited to E.O. 13224 and P.L. 107-56, prohibit transactions with, and the
    provision of resources and support to, individuals and organizations associated with terrorism. It is the legal responsibility of the Contractor to ensure compliance with these Executive Orders and Laws. This clause must be included in all subcontracts
    issued under this contract.

   

  	ARTICLE H.18.	RESTRICTION ON PORNOGRAPHY ON COMPUTER NETWORKS


   

  The Contractor shall not use contract funds to maintain or establish a computer network unless such network blocks the viewing, downloading, and exchanging of pornography.

   

  	ARTICLE H.19.	CERTIFICATION OF FILING AND PAYMENT OF TAXES


   

  The Contractor must be in compliance with Section 518 of the Consolidated Appropriations Act of FY 2014.

   

  	ARTICLE H.20.	ELECTRONIC INFORMATION AND TECHNOLOGY ACCESSIBILITY NOTICE


   

  		a.	Section 508 of the Rehabilitation Act of 1973 (29 U.S.C. 794d), as amended by the Workforce Investment Act of 1998 and the Architectural and Transportation Barriers Compliance Board Electronic and Information (EIT) Accessibility Standards (36
          CFR part 1194), require that when Federal agencies develop, procure, maintain, or use electronic and information technology, Federal employees with disabilities have access to and use of information and data that is comparable to the access and
          use by Federal employees who are not individuals with disabilities, unless an undue burden would be imposed on the agency. Section 508 also requires that individuals with disabilities, who are members of the public seeking information or services
          from a Federal agency, have access to and use of information and data that is comparable to that provided to the public who are not individuals with disabilities, unless an undue burden would be imposed on the agency.


   

  		b.	Accordingly, any Offeror responding to this solicitation must comply with established HHS EIT accessibility standards. Information about Section 508 is available at http://www.hhs.gov/web/508. The complete text of the Section 508 Final
          Provisions can be accessed at http://www.access-board.gov/sec508/standards.htm.


   

  		c.	The Section 508 accessibility standards applicable to this solicitation are stated in the clause at 352.239-74, Electronic and Information Technology Accessibility.


   

  In order to facilitate the Government’s determination whether proposed EIT supplies meet applicable Section 508
      accessibility standards, Offerors must submit an HHS Section 508 Product Assessment Template, in accordance with its completion instructions. The purpose of the template is to assist HHS acquisition and program officials in determining whether
      proposed EIT supplies conform to applicable Section 508 accessibility standards. The template allows Offerors or developers to self-evaluate their supplies and document--in detail--whether they conform to a specific Section 508 accessibility
      standard, and any underway remediation efforts addressing conformance issues. Instructions for preparing the HHS Section 508 Evaluation Template are available under Section 508 policy on the HHS Web site http://hhs.gov/web/508.

   

  In order to facilitate the Government’s determination whether proposed EIT services meet applicable Section 508 accessibility standards, Offerors must provide enough information
    to assist the Government in determining that the EIT services conform to Section 508 accessibility standards, including any underway remediation efforts addressing conformance issues.

   

  		d.	Respondents to this solicitation must identify any exception to Section 508 requirements. If a Offeror claims its supplies or services meet applicable Section 508 accessibility standards, and it is later determined by the Government, i.e.,
          after award of a contract or order, that supplies or services delivered do not conform to the described accessibility standards, remediation of the supplies or services to the level of conformance specified in the contract will be the
          responsibility of the Contractor at its expense.


   

  (End of provision)

   

  

  
  
    	33


  

  
    	 


  

  
   

  	ARTICLE H. 21.	FULL EARNED VALUE MANAGEMENT SYSTEM, HHSAR 352.234-3 (October 2008) with ALTERNATE I (October 2008)


   

  		a.	The Contractor shall use an Earned Value Management System (EVMS) that is compliant with the guidelines in ANSI/EIA Standard-748 (current version at the time of award) to manage this contract. If the Contractor’s
          current EVMS is not compliant at the time of award, see paragraph (b) of this clause. The Contractor shall submit EVM reports in accordance with the requirements of this contract.


   

  		b.	If, at the time of award, the Contractor’s EVM system is not in compliance with the EVMS guidelines in ANSI/EIA Standard-748 (current version at time of award), the Contractor shall:


   

  		a.	Apply the current system to the contract; and


  

  		b.	Take necessary and timely actions to meet the milestones in the Contractor’s EVMS plan approved by the Contracting Officer.


   

  		c.	HHS will not formally validate or accept the Contractor’s EVMS with respect to this contract. The use of the Contractor’s EVMS for this contract does not imply HHS acceptance of the Contractor’s EVMS for application to future contracts. The
          Contracting Officer or designee will conduct a Compliance Review to assess the Contractor’s compliance with its approved plan. If the Contractor does not follow the approved implementation schedule or correct all resulting system deficiencies
          noted during the Compliance Review within a reasonable time, the Contracting Officer may take remedial action that may include, but is not limited to, suspension of or reduction in progress payments, or a reduction in fee.


   

  		d.	HHS will conduct a Performance Measurement Baseline Review (PMBR). If a pre-award PMBR has not been conducted, a post-award PMBR will be conducted by HHS as early as practicable, but no later than ninety (90) days after contract award. The
          Contracting Officer may also require a PMBR as part of the exercise of an option or the incorporation of a major modification.


   

  		e.	The Contractor shall provide access to all pertinent records and data requested by the Contracting Officer or a duly authorized representative as necessary to permit Government surveillance to ensure that the EVMS conforms, and continues to
          conform to the requirements referenced in paragraph (a) of this clause.


   

  		f.	The Contractor shall require the subcontractors specified below to comply with the requirements of the clause:


   

  	ARTICLE H. 22.	CONFIDENTIALITY OF INFORMATION


   

  		a.	Confidential information, as used in this article, means information or data of a personal nature about an individual, or proprietary information or data submitted by or pertaining to an institution or organization.


   

  		b.	The Contracting Officer and the Contractor may, by mutual consent, identify elsewhere in this contract specific information and/or categories of information which the Government will furnish to the Contractor or that the Contractor is expected
          to generate which is confidential. Similarly, the Contracting Officer and the Contractor may, by mutual consent, identify such confidential information from time to time during the performance of the contract. Failure to agree will be settled
          pursuant to the “Disputes” clause.


   

  
  
    	34


  

  
    	 


  

  
   

  

   

  		c.	If it is established elsewhere in this contract that information to be utilized under this contract, or a portion thereof, is
            subject to the Privacy Act, the Contractor will follow the rules and procedures of disclosure set forth in the Privacy Act of 1974, 5 U.S.C. 552a, and implementing regulations and policies, with respect to systems of records determined to be
            subject to the Privacy Act.


   

  		d.	Confidential information, as defined in paragraph (a) of this article, shall not be disclosed without the prior written consent
            of the individual, institution, or organization.


   

  		e.	Whenever the Contractor is uncertain with regard to the proper handling of material under the contract, or if the material in
            question is subject to the Privacy Act or is confidential information subject to the provisions of this article, the Contractor shall obtain a written determination from the Contracting Officer prior to any release, disclosure, dissemination,
            or publication.


   

  		f.	Contracting Officer determinations will reflect the result of internal coordination with appropriate program and legal officials.


   

  The provisions of paragraph (d) of this article shall
      not apply to conflicting or overlapping provisions in other Federal, State or local laws.

   

  ARTICLE H.23.      INSTITUTIONAL RESPONSIBILITY REGARDING
      INVESTIGATOR CONFLICTS OF INTERESTS

   

  The Institution (includes any Contractor, public or
      private, excluding a Federal agency) shall comply with the requirements of 45 CFR Part 94, Responsible Prospective Contractors, which promotes objectivity in research by establishing standards to ensure that Investigators (defined as the project
      director or principal Investigator and any other person, regardless of title or position, who is responsible for the design, conduct, or reporting of research funded under BARDA contracts, or proposed for such funding, which may include, for example,
      collaborators or consultants) will not be biased by any Investigator financial conflicts of interest. 45 CFR Part 94 is available at the following Web site: http://www.ecfr.gov/cgi- bin/text-

        idx?c=ecfr&SID=0af84ca649a74846f102aaf664da1623&rgn=div5&view=text&node=45:1.0.1.1.51&idno= 45

   

  As required by 45 CFR Part 94, the Institution shall, at
      a minimum:

   

  		a.	Maintain an up-to-date, written, enforceable policy on financial conflicts of interest that complies with 45 CFR Part 94, inform each Investigator of the policy, the
            Investigator’s reporting responsibilities regarding disclosure of significant financial interests, and the applicable regulation, and make such policy available via a publicly accessible Web site, or if none currently exist, available to any
            requestor within five business days of a request. A significant financial interest means a financial interest consisting of one or more of the following interests of the Investigator (and those of the Investigator’s spouse and dependent
            children) that reasonably appears to be related to the Investigator’s institutional responsibilities:


    

  		1.	With regard to any publicly traded entity, a significant financial interest exists if the value of any remuneration received from
            the entity in the twelve months preceding the disclosure and the value of any equity interest in the entity as of the date of disclosure, when aggregated, exceeds $5,000. Included are payments and equity interests;


  

  		2.	With regard to any non-publicly traded entity, a significant financial interest exists if the value of any remuneration received
            from the entity in the twelve months preceding the disclosure, when aggregated, exceeds $5,000, or when the Investigator (or the Investigator’s spouse or dependent children) holds any equity interest; or


  

  		3.	Intellectual property rights and interests, upon receipt of income related to such rights and interest.


   

  

  
  
    	35


  

  
    	 


  

  
   

  Significant financial interests do not include the
      following:

   

  		4.	Income from seminars, lectures, or teaching, and service on advisory or review panels for government agencies, Institutions of
            higher education, academic teaching hospitals, medical centers, or research institutes with an Institution of higher learning; and


  

  		5.	Income from investment vehicles, such as mutual funds and retirement accounts, as long as the Investigator does not directly
            control the investment decisions made in these vehicles.


   

  		b.	Require each Investigator to complete training regarding the Institution’s financial conflicts of interest policy prior to
            engaging in research related to any BARDA funded contract and at least every four years. The Institution must take reasonable steps [see Part 94.4(c)] to ensure that investigators working as collaborators, consultants or subcontractors comply
            with the regulations.


   

  		c.	Designate an official(s) to solicit and review disclosures of significant financial interests from each Investigator who is
            planning to participate in, or is participating in, the BARDA funded research.


   

  		d.	Require that each Investigator who is planning to participate in the BARDA funded research disclose to the Institution’s
            designated official(s) the Investigator’s significant financial interest (and those of the Investigator’s spouse and dependent children) no later than the date of submission of the Institution’s proposal for BARDA funded research. Require that
            each Investigator who is participating in the BARDA funded research to submit an updated disclosure of significant financial interests at least annually, in accordance with the specific time period prescribed by the Institution during the
            period of the award as well as within thirty days of discovering or acquiring a new significant financial interest.


   

  		e.	Provide guidelines consistent with the regulations for the designated official(s) to determine whether an Investigator’s
            significant financial interest is related to BARDA funded research and, if so related, whether the significant financial interest is a financial conflict of interest. An Investigator’s significant financial interest is related to BARDA funded
            research when the Institution, thorough its designated official(s), reasonably determines that the significant financial interest: Could be affected by the BARDA funded research; or is in an entity whose financial interest could be affected by
            the research. A financial conflict of interest exists when the Institution, through its designated official(s), reasonably determines that the significant financial interest could directly and significantly affect the design, conduct, or
            reporting of the BARDA funded research.


   

  		f.	Take such actions as necessary to manage financial conflicts of interest, including any financial conflicts of a subcontractor
            Investigator. Management of an identified financial conflict of interest requires development and implementation of a management plan and, if necessary, a retrospective review and mitigation report pursuant to Part 94.5(a).


   

  		g.	Provide initial and ongoing FCOI reports to the Contracting Officer pursuant to Part 94.5(b).


   

  		h.	Maintain records relating to all Investigator disclosures of financial interests and the Institution’s review of, and response
            to, such disclosures, and all actions under the Institution’s policy or retrospective review, if applicable, for at least 3 years from the date of final payment or, where applicable, for the other time periods specified in 48 CFR Part 4,
            subpart 4.7, Contract Records Retention.


   

  		i.	Establish adequate enforcement mechanisms and provide for employee sanctions or other administrative actions to ensure
            Investigator compliance as appropriate.


   

  		j.	Complete the certification in Section K - Representations, Certifications, and Other Statements of Contractors titled “Certification of Institutional Policy on
            Financial Conflicts of Interest”.


   

  

  
  
    	36


  

  
    	 


  

  
   

  If the failure of an Institution to comply with an
      Institution’s financial conflicts of interest policy or a financial conflict of interest management plan appears to have biased the design, conduct, or reporting of the BARDA funded research, the Institution must promptly notify the Contracting
      Officer of the corrective action taken or to be taken. The Contracting Officer will consider the situation and, as necessary, take appropriate action or refer the matter to the Institution for further action, which may include directions to the
      Institution on how to maintain appropriate objectivity in the BARDA funded research project.

   

  The Contracting Officer and/or HHS may inquire at
      any time before, during, or after award into any Investigator disclosure of financial interests, and the Institution’s review of, and response to, such disclosure, regardless of whether the disclosure resulted in the Institution’s determination of a
      financial conflict of interests. The Contracting Officer may require submission of the records or review them on site. On the basis of this review of records or other information that may be available, the Contracting Officer may decide that a
      particular financial conflict of interest will bias the objectivity of the BARDA funded research to such an extent that further corrective action is needed or that the Institution has not managed the financial conflict of interest in accordance with
      Part 94.6(b). The issuance of a Stop Work Order by the Contracting Officer may be necessary until the matter is resolved.

   

  If the Contracting Officer determines that BARDA funded
      clinical research, whose purpose is to evaluate the safety or effectiveness of a drug, medical device, or treatment, has been designed, conducted, or reported by an Investigator with a financial conflict of interest that was not managed or reported
      by the Institution, the Institution shall require the Investigator involved to disclose the financial conflict of interest in each public presentation of the results of the research and to request an addendum to previously published presentations.

   

  ARTICLE H.24.      PUBLICATION AND PUBLICITY

   

  The Contractor shall acknowledge the support of the Department
      of Health and Human Services, Office of the Assistant Secretary for Preparedness and Response, Biomedical Advanced Research and Development Authority whenever publicizing the work under this contract in any media by including an acknowledgment
      substantially as follows:

   

  “This project has been funded in whole or in part with Federal
      funds from the Office of the Assistant Secretary for Preparedness and Response, Biomedical Advanced Research and Development Authority, under Contract No. HHSO100201500035C

   

  Press Releases:

   

  The Contractor shall clearly state, when issuing
      statements, press releases, requests for proposals, bid solicitations and other documents describing projects or programs funded in whole or in part with Federal money that: (1) the percentage of the total costs of the program or project which will
      be financed with Federal money; (2) the dollar amount of Federal funds for the project or program; and (3) the percentage and dollar amount of the total costs of the project or program that will be financed by non-Governmental sources.

   

  ARTICLE H.25.      ACCESS TO DOCUMENTATION/DATA

   

  The Government shall have physical and electronic access to
      all documentation and data generated under this contract, including: all data documenting Contractor performance, all data generated, all communications and correspondence with regulatory agencies and bodies to include all audit observations,
      inspection reports, milestone completion documents, and all Contractor commitments and responses. Contractor shall provide the Government with an electronic copy of all correspondence with the FDA within 24 hours of receipt. The Government shall
      acquire unlimited rights to all data funded under a contract awarded in response to this RFP in accordance with FAR Subpart 27.4 and FAR Clause 52.227-14.

   

  

  
  
    	37


  

  
    	 


  

  
   

  ARTICLE H.26.      DISSEMINATION OF INFORMATION

   

  No information related to data obtained under this
      contract shall be released or publicized without the prior written consent of the COR, whose approval shall not be unreasonably withheld, conditioned, or delayed, provided that no such consent is required to comply with any law, rule, regulation,
      court ruling or similar order; for submission to any government entity’ for submission to any securities exchange on which the Contractor’s (or its parent corporation’s) securities may be listed for trading; or to third parties relating to securing,
      seeking, establishing or maintaining regulatory or other legal approvals or compliance, financing and capital raising activities, or mergers, acquisitions, or other business transactions.

   

  ARTICLE H.27.      DISSEMINATION OF FALSE OR DELIBERATELY MISLEADING
      INFORMATION

   

  The Contractor shall not use contract funds to
      disseminate information that is deliberately false or misleading.

   

  ARTICLE H.28.      IDENTIFICATION AND DISPOSITION OF DATA

   

  The Contractor will be required to provide certain
      data generated under this contract to the Department of Health and Human Services (HHS). HHS reserves the right to review any other data determined by HHS to be relevant to this contract. The Contractor shall keep copies of all data required by the
      Food and Drug Administration (FDA) relevant to this contract for the time specified by the FDA.

   

  ARTICLE H.29.      CONFLICT OF INTEREST

   

  The Contractor represents and warrants that, to the
      best of the Contractor’s knowledge and belief, there are no relevant facts or circumstances which could give rise to an organizational conflict of interest, as defined in FAR 2.101 and Subpart 9.5, or that the Contractor has disclosed all such
      relevant information. Prior to commencement of any work, the Contractor agrees to notify the Contracting Officer promptly that, to the best of its knowledge and belief, no actual or potential conflict of interest exists or to identify to the
      Contracting Officer any actual or potential conflict of interest the firm may have. In emergency situations, however, work may begin but notification shall be made within five (5) working days. The Contractor agrees that if an actual or potential
      organizational conflict of interest is identified during performance, the Contractor shall promptly make a full disclosure in writing to the Contracting Officer. This disclosure shall include a description of actions which the Contractor has taken or
      proposes to take, after consultation with the Contracting Officer, to avoid, mitigate, or neutralize the actual or potential conflict of interest. The Contractor shall continue performance until notified by the Contracting Officer of any contrary
      action to be taken. Remedies include termination of this contract for convenience, in whole or in part, if the Contracting Officer deems such termination necessary to avoid an organizational conflict of interest. If the Contractor was aware of a
      potential organizational conflict of interest prior to award or discovered an actual or potential conflict after award and did not disclose it or misrepresented relevant information to the Contracting Officer, the Government may terminate the
      contract for default, debar the Contractor from Government contracting, or pursue such other remedies as may be permitted by law or this contract.

   

  ARTICLE H.30.      IN-PROCESS REVIEW

   

  In Process Reviews (IPR) will be conducted at the
      discretion of the Government to discuss the progression of the milestones. The Government reserves the right to revise the milestones and budget pending the development of the project. Deliverables may be required when the IPRs are conducted. The
      Contractor’s success in completing the required tasks under each work segment must be demonstrated through the Deliverables and Milestones specified under SECTION F. Those deliverables will constitute the basis for the Government’s decision, at its
      sole discretion, to proceed with the work segment, or unilaterally institute changes to the work segment, or terminate the work segment.

   

  IPRs may be scheduled at the discretion of the
      Government to discuss progression of the contract. The Contractor shall provide a presentation following a prescribed template which will be provided by the Government at least 30 days prior to the IPR. The Contractor shall provide a draft
      presentation to the Contracting Officer at least 10 days prior to the IPR.

   

  

  
  
    	38


  

  
    	 


  

  
   

  ARTICLE H.31.      PRIVACY ACT APPLICABILITY

   

  		1)	Notification is hereby given that the Contractor and its employees are subject to criminal penalties for violation of the Privacy
            Act to the same extent as employees of the Government. The Contractor shall assure that each of its employees knows the prescribed rules of conduct and that each is aware that he or she can be subjected to criminal penalty for violation of the
            Act. A copy of 45 CFR Part 5b, Privacy Act Regulations, may be obtained at http://www.gpoaccess.gov/cfr/index.html


   

  		2)	The Project Officer is hereby designated as the official who is responsible for monitoring contractor compliance with the Privacy
            Act.


   

  		3)	The Contractor shall follow the Privacy Act guidance as contained in the Privacy Act System of Records number 09-25-0200. This
            document may be obtained at the following link: http://oma.od.nih.gov/ms/privacy/pa-files/0200.htm


   

  ARTICLE H.32.      QA AUDIT REPORTS

   

  BARDA reserves the right to participate in QA audits.
      Upon completion of the audit/site visit the Contractor shall provide a report capturing the findings, results and next steps in proceeding with the subcontractor. If action is requested of the subcontractor, detailed concerns for addressing areas of
      non-conformance to FDA regulations for GLP, GMP, or GCP guidelines, as identified in the audit report, must be provided to BARDA. The Contractor shall provide responses from the subcontractors to address these concerns and plans for corrective action
      execution.

   

  		·	Contractor shall notify CO and COR of upcoming, ongoing, or recent audits/site visits of subcontractors as part of weekly communications. The
            Contractor shall notify the CO and COR reasonably in advance of upcoming QA audit so that Government personnel may participate in person at BARDA’s discretion.


  

  		·	Contractor shall notify the COR and CO within 5 business days of report completion.


   

  ARTICLE H.33.      BARDA AUDITS

   

  Contractor shall accommodate periodic or ad hoc site
      visits by the Government. If the Government, the Contractor, or other parties identifies any issues during an audit, the Contractor shall capture the issues, identify potential solutions, and provide a report to the Government.

   

  		·	If issues are identified during the audit, Contractor shall submit a report to the CO and COR detailing the finding and corrective action(s) within 10
            business days of the audit.


  

  		·	COR and CO will review the report and provide a response to the Contractor with 10 business days.


  

  		·	Once corrective action is completed, the Contractor will provide a final report to the CO and COR.


   

  

  ARTICLE H.34.   SECURITY REPORTING REQUIREMENT

   

  Violations of established security protocols shall be
      reported to the CO and COR upon discovery within 24 hours of its receipt of any compromise, intrusion, loss or interference of its security processes and procedures. The Contractor shall ensure that all software components that are not required for
      the operation and maintenance of the database/control system has been removed and/or disabled. The Contractor shall provide to the CO and the COR information appropriate to Information and Information Technology software and service updates and/or
      workarounds to mitigate all vulnerabilities associated with the data and shall maintain the required level of system security.

   

  

  
  
    	39


  

  
    	 


  

  
   

  The Contractor will investigate violations to determine
      the cause, extent, loss or compromise of sensitive program information, and corrective actions taken to prevent future violations. The CO in coordination with BARDA will determine the severity of the violation. Any contractual actions resulting from
      the violation will be determined by the CO.

   

  

  
  
    	40


  

  
    	 


  

  
   

   

  

  

  PART II – CONTRACT CLAUSES

   

  SECTION I - CONTRACT CLAUSES

   

  ARTICLE I.1. FAR 52.252-2, CLAUSES INCORPORATED BY REFERENCE (FEBRUARY 1998)

   

  This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text.
      Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses: https://www.acquisition.gov/FAR/. HHSAR Clauses at: http://www.hhs.gov/policies/hhsar/subpart352.html.

   

  General Clauses for Cost-Reimbursement/Fixed Price Research and Development Contract

   

  (1)         FEDERAL ACQUISITION REGULATION (FAR) (48 CFR CHAPTER 1) CLAUSES:

   

  	Reg	Clause	Date	Clause Title
	FAR	52.202-1	Nov 2013	Definitions
	FAR	52.203-3	Apr 1984	Gratuities
	FAR	52.203-5	May 2014	Covenant Against Contingent Fees
	FAR	52.203-6	Sep 2006	Restrictions on Subcontractor Sales to the Government
	FAR	52.203-7	May 2014	Anti-Kickback Procedures
	FAR	52.203-8	May 2014	Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity
	FAR	52.203-10	May 2014	Price or Fee Adjustment for Illegal or Improper Activity
	FAR	52.203-12	Oct 2010	Limitation on Payments to Influence Certain Federal Transactions
	FAR	52.203-13	Apr 2010	Contractor Code of Business Ethics and Conduct
	FAR	52.203-14	Dec 2007	Display of Hotline Posters
	FAR	52.203-17	Apr 2014	Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights
	FAR	52.204-4	May 2011	Printed or Copied Double-Sided on Postconsumer Fiber Content Paper
	FAR	52.204-7	Jul 2013	System for Award Management
	FAR	52.204-10	Jul 2013	Reporting Executive Compensation and First-Tier Subcontract Awards
	FAR	52.204-13	Jul 2013	System for Award Management Maintenance
	FAR	52.209-6	Aug 2013	Protecting the Government’s Interests When Subcontracting With Contractors Debarred, Suspended, or
            Proposed for Debarment
	FAR	52.209-10	Dec 2014	Prohibition on Contracting with Inverted Domestic Corporations
	FAR	52.210-1	Apr 2011	Market Research
	FAR	52.215-2	Oct 2010	Audit and Records – Negotiation
	FAR	52.215-8	Oct 1997	Order of Precedence - Uniform Contract Format
	FAR	52.215-10	Aug 2011	Price Reduction for Defective Cost or Pricing Data
	FAR	52.215-11	Aug 2011	Price Reduction for Defective Certified Cost or Pricing Data—Modifications.
	FAR	52.215-12	Oct 2010	Subcontractor Certified Cost or Pricing Data
	FAR	52.215-13	Oct 2010	Subcontractor Certified Cost or Pricing Data—Modifications
	FAR	52.215-15	Oct 2010	Pension Adjustments and Asset Reversions
	FAR	52.215-18	Jul 2005	Reversion or Adjustment of Plans for Postretirement Benefits (PRB) other than Pensions
	FAR	52.215-19	Oct 1997	Notification of Ownership Changes
	FAR	52.215-21	Oct 2010	Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data
            -Modifications
	FAR	52.215-23	Oct 2009	Limitations on Pass-Through Charges
	FAR	52.216-7	Jun 2013	Allowable Cost and Payment
	FAR	52.216-8	Jun 2011	Fixed Fee
	FAR	52.219-8	Oct 2014	Utilization of Small Business Concerns
	FAR	52.219-28	July 2013	Post-Award Small Business Program Representation
	FAR	52.222-1	Feb 1997	Notice to the Government of Labor Disputes


   

  

  
  
    	41


  

  
    	 


  

  
   

  	FAR	52.222-2	Jul 1990	Payment for Overtime Premiums
	FAR	52.222-3	Jun2003	Convict Labor
	FAR	52.222-21	Apr 2015	Prohibition of Segregated Facilities
	FAR	52.222-26	Apr 2015	Equal Opportunity
	FAR	52.222-35	Jul 2014	Equal Opportunity for Veterans
	FAR	52.222-36	Jul 2014	Equal Opportunity for Workers with Disabilities
	FAR	52.222-37	Jul 2014	Employment Reports on Veterans
	FAR	52.222-40	Dec 2010	Notification of Employee Rights Under the National Labor Relations Act
	FAR	52.222-50	Mar 2015	Combating Trafficking in Persons
	FAR	52.222-54	Aug 2013	Employment Eligibility Verification
	FAR	52.223-6	May 2001	Drug-Free Workplace
	FAR	52.223-18	Aug 2011	Encouraging Contractor Policy to Ban Text Messaging While Driving
	FAR	52.224-1	April 1984	Privacy Act Notification
	FAR	52.224-2	April 1984	Privacy Act
	FAR	52.225-13	Jun 2008	Restrictions on Certain Foreign Purchases
	FAR	52.227-1	Dec 2007	Authorization and Consent, Alternate 1 (APR 1984)
	FAR	52.227-2	Dec 2007	Notice and Assistance Regarding Patent and Copyright Infringement
	FAR	52.227-3	Apr 1984	Patent Indemnity
	FAR	52.227-11	May 2014	Patent Rights – Ownership by the Contractor
	FAR	52.227-14	May 2014	Rights in Data - General
	FAR	52.227-14	Dec 2007	Alt II
	FAR	52.228-7	Mar 1996	Insurance – Liability to Third Persons
	FAR	52.229-3	Feb 2013	Federal, State and Local Taxes
	FAR	52.230-4	May 2014	Disclosure and Consistency of Cost Accounting Practices—Foreign Concerns
	FAR	52.230-6	June 2010	Administration of Cost Accounting Standards
	FAR	52.232-1	Apr 1984	Payments
	FAR	52.232-2	Apr 1984	Payments under Fixed-Price Research and Development Contracts
	FAR	52.232-8	Feb 2002	Discounts for Prompt Payment
	FAR	52.232-9	Apr 1984	Limitation on Withholding of Payments
	FAR	52.232-11	Apr 1984	Extras
	FAR	52.232-17	May 2014	Interest
	FAR	52.232-20	Apr 1984	Limitation of Cost
	FAR	52.232-23	May 2014	Assignment of Claims
	FAR	52.232-25	Jul 2013	Prompt Payment
	FAR	52.232-33	Jul 2013	Payment by Electronic Funds Transfer--System for Award Management
	FAR	52.233-1	May 2014	Disputes
	FAR	52.233-3	Aug 1996	Protest After Award, Alternate I
	FAR	52.233-4	Oct 2004	Applicable Law for Breach of Contract Claim
	FAR	52.242-1	Apr 1984	Notice of Intent to Disallow Costs
	FAR	52.242-3	May 2014	Penalties for Unallowable Costs
	FAR	52.242-4	Jan 1997	Certification of Final Indirect Costs
	FAR	52.242-13	Jul 1995	Bankruptcy
	FAR	52.242-15	Aug 1989	Stop Work Order, Alternate I (Aug 1984)
	FAR	52.243-1	Aug 1987	Changes - Fixed-Price Alternate V (Apr 1984).
	FAR	52.243-2	Aug 1987	Changes—Cost-Reimbursement Alternate V (Apr 1984).
	FAR	52.243-7	Apr 1984	Notification of Changes
	FAR	52.244-2	Oct 2010	Subcontracts, Alternate 1 (Jun 2007)
	FAR	52.244-5	Dec 1996	Competition in Subcontracting
	FAR	52.244-6	Apr 2015	Subcontracts for Commercial Items
	FAR	52.245-1	Apr 2012	Government Property
	FAR	52.245-9	Apr 2012	Use and Charges
	FAR	52.246-23	Feb 1997	Limitation of Liability.
	FAR	52.246-25	Feb 1997	Limitation of Liability—Services
	FAR	52.248-1	October 2010	Value Engineering
	FAR	52.249-2	Apr 2012	Termination for the Convenience of the Government (Fixed-Price)
	FAR	52.249-6	May 2004	Termination (Cost-Reimbursement)
	FAR	52.249-8	Apr 1984	Default (Fixed-Price Supply and Service)
	FAR	52.249-9	Apr 1984	Default (Fixed-Price Research and Development)
	FAR	52.249-14	Apr 1984	Excusable Delays
	FAR	52.253-1	Jan 1991	Computer Generated Forms


   

  

  
  
    	42


  

  
    	 


  

  
   

  (2) DEPARTMENT OF HEALTH AND HUMAN SERVICES ACQUISITION REGULATION (HHSAR) (48 CFR CHAPTER 3) CLAUSES:

   

  	HHSAR	352.201-70	Sept 2010	Paperwork Reduction Act
	HHSAR	352.202-1	Jan 2006	Definitions - with Alternate paragraph (h)
	HHSAR	352.203-70	Mar 2012	Anti-Lobbying
	HHSAR	352.216-70	Jan 2006	Additional Cost Principles
	HHSAR	352.222-70	Jan 2010	Contractor Cooperation in Equal Employment Opportunity Investigations
	HHSAR	352.223-70	Sept 2010	Safety and Health
	HHSAR	352.224-70	Jan 2006	Privacy Act
	HHSAR	352.227-70	Jan 2006	Publications and Publicity
	HHSAR	352.228-7	Dec 1991	Insurance - Liability to Third Persons
	HHSAR	352.231-70	Jan 2006	Salary Rate Limitation
	HHSAR	352.231-71	Jan 2001	Pricing of Adjustments
	HHSAR	352.233-71	Jan 2006	Litigation and Claims
	HHSAR	352.242-70	Jan 2006	Key Personnel
	HHSAR	352.242-73	Jan 2006	Withholding of Contract Payments
	HHSAR	352.242-74	Apr 1984	Final Decisions on Audit Findings


   

  ARTICLE I.2. ADDITIONAL CONTRACT CLAUSES

   

  This contract incorporates the following clauses by reference, with the same force and effect, as if they were given in full text.
      Upon request, the Contracting Officer will make their full text available.

   

  a. FEDERAL ACQUISITION REGULATION (FAR) (48 CFR CHAPTER 1) CLAUSES

   

  1.   FAR 52.215-17, Waiver of Facilities Capital Cost of Money (October 1997). 

  2.   FAR 52.227-16, Additional Data Requirements (June 1987).

   

  ARTICLE I.3. ADDITIONAL FAR CLAUSES INCLUDED IN FULL TEXT

   

  352.231-70 Salary rate limitation (August 2012)

   

  1.      Pursuant to the current and applicable prior HHS appropriations acts, the Contractor shall
      not use contract funds to pay the direct salary of an individual at a rate in excess of the Federal Executive Schedule Level II in effect on the date an expense is incurred.

   

  2.      For purposes of the salary rate limitation, the terms “direct salary,” “salary”, and
      “institutional base salary”, have the same meaning and are collectively referred to as “direct salary”, in this clause. An individual’s direct salary is the annual compensation that the Contractor pays for an individual’s direct effort (costs) under
      the contract. Direct salary excludes any income that an individual may be permitted to earn outside of duties to the Contractor. Direct salary also excludes fringe benefits, overhead, and general and administrative expenses (also referred to as
      indirect costs or facilities and administrative [F&A] costs).

   

  

  
  
    	43


  

  
    	 


  

  
   

  Note: The salary rate limitation does not restrict the salary that an organization may pay an individual working under an
      HHS contract or order; it merely limits the portion of that salary that may be paid with Federal funds.

   

  1.      The salary rate limitation also applies to individuals under subcontracts. If this is a
      multiple-year contract or order, it may be subject to unilateral modification by the Contracting Officer to ensure that an individual is not paid at a rate that exceeds the salary rate limitation provision established in the HHS appropriations act in
      effect when the expense is incurred regardless of the rate initially used to establish contract or order funding.

   

  2.      See the salaries and wages pay tables on the U.S. Office of Personnel Management Web site for
      Federal Executive Schedule salary levels that apply to the current and prior periods.

   

  FAR 52.217-7 Option for Increased Quantity-Separately Priced Line Item (Mar 1989)

   

  The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and
      at the price stated in the Schedule. The Contracting Officer may exercise the option by written notice to the Contractor within 30 days. Delivery of added items shall continue at the same rate that like items are called for under the
      contract, unless the parties otherwise agree.

   

  FAR 52.217-9 Option to Extend the Term of the Contract (Mar 2000)

   

  (a)  The Government may extend the term of this contract by written notice to the Contractor within
      30 Days provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 30 days before the contract expires. The preliminary notice does not commit the Government to an extension.

   

  (b)  If the Government exercises this option, the extended contract shall be considered to include
      this option clause.

   

  (c)  The total duration of this contract, including the exercise of any options under this clause,
      shall not exceed 8 years.

   

  FAR 52.219-1 Small Business Program Representations (Oct 2014)

  

  	 	 	 
	(a)	(1)	The North American Industry Classification System (NAICS) code for this acquisition is 541711.
	 	(2)	The small business size standard is 500 employees.
	 	(3)	The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did
            not itself manufacture, is 500 employees.
	 	 	 
	(b) Representations.
	 	 	 
	 	(1)	The Offeror represents as part of its offer that it [X] is, [_] is not a small business concern.
	 	 	 
	 	(2)	[Complete only if the Offeror represented itself as a small business concern in paragraph (b)(1) of this provision.] The Offeror represents, for general statistical purposes, that it
            [_] is, [X] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.
	 	 	 
	 	(3)	[Complete only if the Offeror represented itself as a small business concern in paragraph (b)(1) of this provision.] The Offeror represents as part of its offer that it [X] is, [_]
            is not a women-owned small business concern.


   

  

  
  
    	44


  

  
    	 


  

  
   

  	 	 	 
	 	(4)	Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the Offeror represented itself as a women-owned small business concern in paragraph (b)(3) of
            this provision.] The Offeror represents as part of its offer that—
	 	 	
          (i)   It [_] is, [X] is not a WOSB concern eligible under the WOSB Program, has provided all
              the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and 

          (ii)  It [_] is, [X] is not a joint venture that complies with the requirements of 13 CFR
              part 127, and the representation in paragraph (b)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern
              eligible under the WOSB Program and other small businesses that are participating in the joint venture: __________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of
              the WOSB representation.

        
	 	 	 
	 	(5)	Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB
            Program in (b)(4) of this provision.] The Offeror represents as part of its offer that—
	 	 	 
	 	 	
          (i)   It [_] is, [X] is not an EDWOSB concern eligible under the WOSB Program, has provided
              all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and 

          (ii)  It [_] is, [X] is not a joint venture that complies with the requirements of 13 CFR
              part 127, and the representation in paragraph (b)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The Offeror shall enter the name or names of the EDWOSB concern and other small businesses that
              are participating in the joint venture: __________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

        
	 	(6)	[Complete only if the Offeror represented itself as a small business concern in paragraph (b)(1) of this provision.] The Offeror represents as part of its offer that it [_]
            is, [X] is not a veteran-owned small business concern.
	 	 	 
	 	(7)	[Complete only if the Offeror represented itself as a veteran-owned small business concern in paragraph (b)(6) of this provision.] The Offeror represents as part of its offer that is [_]
            is, [_] is not a service-disabled veteran-owned small business concern.
	 	 	 
	 	(8)	[Complete only if the Offeror represented itself as a small business concern in paragraph (b)(1) of this provision.] The Offeror represents, as part of its offer, that –
	 	 	 
	 	 	
          (i)  It [_] is, [X] is not a HUBZone small business concern listed, on the date of this
              representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since
              it was certified in accordance with 13 CFR part 126; and 

          (ii)  It [_] is, [X] is not a HUBZone joint venture that complies with the requirements of 13
              CFR part 126, and the representation in paragraph (b)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small
                business concerns participating in the HUBZone joint venture: __________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

        


   

  

  
  
    	45


  

  
    	 


  

  
   

  	 	 	 
	(c) Definitions. As used in this provision—
	 	 	 
	 	“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and
            the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a
            women-owned small business concern eligible under the WOSB Program.
	 	“Service-disabled veteran-owned small business concern”—
	 	 
	 	(1)   Means a small business concern—
	 	 	
          (i)   Not less than 51 percent of which is owned by one or more service-disabled veterans
              or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and 

          (ii)  The management and daily business operations of which are controlled by one or more
              service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

        
	 	 	 
	 	 (2)  Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as
            defined in 38 U.S.C. 101(16).
	 	 	 
	 	
          “Small business concern,” means a concern, including its affiliates that is independently owned and operated, not dominant
              in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (a) of this provision.

          “Veteran-owned small business concern” means a small business concern—

        
	 	 	 
	 	 (1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any
            publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and 
	 	 (2) The management and daily business operations of which are controlled by one or more veterans.
	 	 	 
	 	“Women-owned small business concern,” means a small business concern –
	 	 	 
	 	(1)	
          That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent
              of the stock of which is owned by one or more women; and

        
	 	(2)	Whose management and daily business operations are controlled by one or more women.
	 	 	 
	 	“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent
            directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.
	 	 	 
	(d) Notice.
	 	 	 
	 	(1)	If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside
            contains restrictions on the source of the end items to be furnished.
	 	 	 
	 	(2)	Under 15 U.S.C. 645(d), any person who misrepresents a firm’s status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small,
            economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small
            Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall –
	 	 	
            (i) Be punished by imposition of fine, imprisonment, or both;

            (ii) Be subject to administrative remedies, including suspension and debarment; and 

            (iii) Be ineligible for participation in programs conducted under the authority of the Act.

        


   

  

  
  
    	46


  

  
    	 


  

  
   

  	 	FAR 52.232-40, Providing Accelerated Payment to Small Business Subcontractors (Dec 2013)
	 	 
	(a)	Upon receipt of accelerated payments from the Government, the Contractor shall make accelerated payments to its small business subcontractors under this contract, to the maximum extent practicable and prior to when such payment is
          otherwise required under the applicable contract or subcontract, after receipt of a proper invoice and all other required documentation from the small business subcontractor.
	 	 
	(b)	The acceleration of payments under this clause does not provide any new rights under the Prompt Payment Act.
	 	 
	(c)	Include the substance of this clause, including this paragraph (c), in all subcontracts with small business concerns, including subcontracts with small business concerns for the acquisition of commercial items.
	 	 	 


  

  

  

  
  
    	47


  

  
    	 


  

  
  

  

   

  

  	 	 	 
	PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS
	 
	SECTION J - LIST OF ATTACHMENTS
	 	 	 
	 	The following documents are attached and incorporated in this contract:
	 	 	 
	 	1.	Statement of Work, dated September 29, 2015
	 	 	 
	 	2.	Invoice/Financing Instructions for Cost-Reimbursement Type Contracts
	 	 	 
	 	3.	Invoice Instructions for Fixed-Priced Type Contracts
	 	 	 
	 	4.	 Sample Invoice Form
	 	 	 
	 	5.	Research Patient Care Costs
	 	 	 
	 	6.	Report of Government Owned, Contractor Held Property
	 	 	 
	 	7.	Form SF-LLL, Disclosure of Lobbying Activities
	 	 	 
	 	8.	Inclusion Enrollment Report, 5/01 (Modified OAMP: 10/01)


   

  
  
    	48


  

  
    	 


  

  
   

  

   

   

  Final Revised Proposal

  Volume II: Technical Proposal

  Full Proposal Submitted for Consideration under Solicitation 15-100-SOL-00021

  Non-Surgical Debridement for Definitive Care of Burn Injuries

  This proposal is made in agreement with all the terms and conditions of this Solicitation.

   

  Advanced Development of NexoBrid 

  as a Medical Countermeasure for Injury Associated 

      with Burns

   

  SOW Portion of the Base pages 66-89

   

  Submitted to: 

  Biomedical Advanced Research and Development Authority

  U.S. Department of Health and Human Services

  Assistant Secretary for Preparedness and Response

  Contracting Officer – Matthew Rose

  ASPR-AMCG-202-205-2901

  200 C St. SW

  Washington, D.C. 20024

  Attention: Matthew Rose, Contracting Officer

   

  	
          Reference: Solicitation # 15-100-SOL-00021

           

          Prime Offeror: 

           

          MediWound Ltd.

          42 Hayarkon Street,

          Yavne, Israel 8122745

          Tel: + +972 77 9714100

          Fax: +972 77 9714111

          e-mail:

            info@mediwound.cominfo@mediwound.com

          DUNS: 5320400334

           

          September 10, 2015

        	
           

           

          Business Contact: 

           

          Gal Cohen

          President & Chief Executive Officer

           

          Technical Contact: 

          Ety Klinger, PhD

          Chief R&D Officer 

        


   

  
  
    	 


  

  
    	 


  

  
   

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


   

  Throughout this proposal, MediWound refers to various trademarks, service marks and trade names that it uses in its business. The “MediWound” design logo,
      “MediWound”, “NexoBrid”, “EscharEx” and other trademarks or service marks of MediWound appearing in this proposal are the property of MediWound. MediWound has several other trademarks, service marks and pending applications relating to its
      applications. Other trademarks and service marks appearing in this proposal are the property of their respective holders.

   

  TABLE OF CONTENTS

   

  	1.1   Statement of Work	5
	1.   Base Period Statement of Work	5
	1.1   Program Management (WBS 1.1)	5
	1.1.1   Technical and Project Management (WBS 1.1.1)	5
	1.1.1.1.   Update Project Schedule (WBS 1.1.1.1)	5
	1.1.1.2.   Complete Project Baseline Schedule (WBS 1.1.1.2)	5
	1.1.1.3.   Complete Integrated Master Project Plan (WBS 1.1.1.3)	5
	1.1.1.4.   Base Period Management (CLIN 0001)/Report (WBS 1.1.1.4)	5
	1.1.2   Subcontractor Management (WBS 1.1.2)	6
	1.1.3   Risk management (WBS 1.1.3)	6
	1.1.4   EVMS (WBS 1.1.4)	7
	1.2   Non Clinical Toxicology (WBS 1.2)	7
	1.2.1   Safety (WBS 1.2.1)	7
	1.2.1.1   [ * * * ] (WBS 1.2.1.1)	8
	1.2.1.2   [ * * * ] (WBS 1.2.1.2)	8
	1.2.1.3   [ * * * ] (WBS 1.2.1.3)	9
	1.2.1.4   [ * * * ] (WBS 1.2.1.4)	9
	1.2.1.5   [ * * * ] (WBS 1.2.1.5)	10
	1.3   Non- Clinical Pharmacology (WBS 1.3)	10
	1.3.1   Mechanism of Action Studies (WBS 1.3.1)	10
	1.3.1.1   [ * * * ] (WBS 1.3.1.1)	11
	1.3.1.2   [ * * * ] (WBS 1.3.1.2)	11
	1.3.1.3   [ * * * ] (WBS 1.3.1.3)	12
	1.3.1.4   [ * * * ] (WBS 1.3.1.4)	12
	1.3.2   Product Characterization (WBS 1.3.2)	13
	1.3.2.6   [ * * * ] (WBS 1.3.2.1)	13
	1.3.3   Efficacy and Safety (WBS 1.3.3)	13
	1.3.3.1   [ * * * ] (WBS 1.3.3.1)	13
	1.4   Clinical (WBS 1.4)	14


   

  

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 2 of 28 


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

   

  
  
    	 


  

  
    	 


  

  
   

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


  

   

  	1.4.1   US phase 3 study (WBS 1.4.1)	14
	1.5   Regulatory	16
	1.5.1   IND	16
	1.5.1.1   [ * * * ] (WBS 1.5.1.1)	16
	1.5.1.2   [ * * * ] (WBS 1.5.1.2)	16
	1.5.1.3   [ * * * ] (WBS 1.5.1.3)	17
	1.5.1.4   [ * * * ] (WBS 1.5.1.4)	17
	1.5.1.5   [ * * * ] (WBS 1.5.1.5)	17
	1.5.1.6   FDA Submission Request For [ * * * ] (WBS 1.5.1.6)	17
	1.5.2   BLA (WBS 1.5.2)	18
	1.5.2.1   [ * * * ] (WBS 1.5.2.1)	18
	1.5.2.2   Pre-BLA Meeting (WBS 1.5.2.2)	18
	1.5.2.3   BLA preparation and submission (WBS 1.5.2.3)	19
	1.6   Chemistry, Manufacturing and Control (CMC) (WBS 1.6)	20
	1.6.1   [ * * * ] (WBS 1.6.1)	20
	1.6.1.1   [ * * * ] (LC-MS) (WBS 1.6.1.1)	20
	1.6.1.2   [ * * * ] (WBS 1.6.1.2)	20
	1.6.1.3   [ * * * ] (WBS 1.6.1.3)	20
	1.6.2   [ * * * ] Development (WBS 1.6.2)	21
	1.6.2.1   [ * * * ] (WBS 1.6.2.1)	21
	1.6.2.2   [ * * * ] (WBS 1.6.2.2)	22
	1.6.2.3   [ * * * ] (WBS 1.6.2.3)	22
	1.6.2.4   [ * * * ] (WBS 1.6.2.4)	22
	1.6.3   Quality by Design (QbD) (WBS 1.6.3)	22
	1.6.3.1   Risk Based Design of Experiment (DOE) Plan (WBS 1.6.3.1)	22
	1.6.3.2   [ * * * ] (WBS 1.6.3.2)	23
	1.6.3.3   Statistical Analysis and Summary of the Results (WBS 1.6.3.3)	23
	1.6.4   Agriculture Raw Material Studies (WBS 1.6.4)	23
	1.6.4.1   [ * * * ] (WBS 1.6.4.1)	24
	1.6.4.2   Analytical Chemistry Testing and Statistical Analysis (WBS 1.6.4.2)	24
	1.6.5   [ * * * ] (WBS 1.6.5)	24
	1.6.5.1   [ * * * ] (WBS 1.6.5.1)	25
	1.6.5.2   [ * * * ] (WBS 1.6.5.2)	25
	1.6.5.3   File Submission, Inspection & Approving (WBS 1.6.5.3)	25


   

  

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 3 of 28 


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


  

   

  	1.6.5.4   [ * * * ] (WBS 1.6.5.4)	26
	1.6.5.5   FDA Approval of Scale-up (WBS 1.6.5.5)	26
	1.7   Procurement (WBS 1.7)	27
	1.7.1   Acquisition (WBS 1.7.1)	27
	1.7.2   Warm Base (Inventory Stockpile) (WBS 1.7.2)	27
	1.7.2.1   Setup of vendor managed inventory system (VMI) plan (WBS 1.7.2.1)	27
	1.7.2.2   Implementation of vendor managed inventory system (VMI) plan (WBS 1.7.2.2)	27
	1.7.3   Sustainment (WBS 1.7.3)	28
	1.7.4   Disposal (WBS 1.7.4)	28


   

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 4 of 28 


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  

   

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

  

   

  		1.1	Statement of Work


   

  The Statement of Work has a separate numb ering system from the section numbers in this document. SOW section numbers correspond to the correct WBS numbers.

   

  		1.	Base Period Statement of Work


   

  		1.1	Program Management (WBS 1.1)


   

  Program Management encompasses contract management (e.g., contract reporting), program management (e.g., subcontractor oversight, program progress), and risk management (e.g., EVM, risk
    evaluation). Project Management milestones and activities in this section are listed below, corresponding to management in the period described.

   

  		1.1.1	Technical and Project Management (WBS 1.1.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.1.1 Technical and Project Management	Successful completion of technical and project management activities for each option period.	Project scheduled completed and reports submitted to BARDA PO/CO after completion of each
          option period.


    

  Objective/Description of Work: These activities encompass all Program Management for the listed contract period.

   

  

  		1.1.1.1.	Update Project Schedule (WBS 1.1.1.1)


   

  		1.1.1.2.	Complete Project Baseline Schedule (WBS 1.1.1.2)


   

  		1.1.1.3.	Complete Integrated Master Project Plan (WBS 1.1.1.3)


   

  		1.1.1.4.	Base Period Management (CLIN 0001)/Report (WBS 1.1.1.4)


   

  Objective/Description of Work: An overall project schedule in the form of a Gantt chart will be created and maintained as part of project management. This schedule will be updated
    and formally completed within 90 days after the contract award.

   

  Milestones:

   

  Complete Project Baseline Schedule (WBS 1.1.1.2)

  Complete Integrated Master Project Plan (WBS 1.1.1.3)

   

  Deliverables: The project schedule will be submitted to the BARDA PO/CO. Reports on these activities will be included as part of regular project status updates to the BARDA PO/CO
    as listed below.

   

  Complete Project Baseline Schedule (WBS 1.1.1.2)

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 5 of 28


  

   

  
  
    	 


  

  
    	 


  

  
  

   

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

  

   

  Complete Integrated Master Project Plan (WBS 1.1.1.3)

  Base Period Management/ Report (WBS 1.1.1.4)

   

  		1.1.2	Subcontractor Management (WBS 1.1.2)


   

  	WBS# and Title	Milestone	Deliverables
	1.1.2 Subcontractor Management	Completion of subcontractor management plan	Subcontractor management plan submitted to BARDA


    

  Objective/Description of Work: Company will compile all necessary materials and finalize all aspects of the project related to preparing the Subcontractor Management Plan,
    including a description of how MediWound will communicate with each subcontractor’s lead representative on a regular basis; monitor subcontractor costs, technical performance, and conformance to schedules; and stay informed of changes and availability
    of the subcontractor’s technical team personnel.

   

  Milestones:

   

  Completion of plan development stages as indicated above within 90 days of award.

  Develop Subcontractor Management Plan (WBS 1.1.2.1)

  Complete Subcontractor Plan and submit to BARDA(WBS 1.1.2.2)

  Implementation of Subcontractor Management Plan (WBS 1.1.2.3)

   

  Deliverables:

   

  		-	Submit subcontractor management plan to BARDA within 90 days of contract award (WBS 1.1.2.2).


   

  		1.1.3	Risk management (WBS 1.1.3)


   

  Objective/Description of Work: MediWound will prepare a Risk Mitigation Plan and Matrix consistent with the template provided by BARDA, and submit such documents to BARDA within 90
    days of contract award. The risk mitigation plan will highlight potential problems and/or issues that may arise during the life of the contract, their impact on cost, schedule and performance, and appropriate remediation plans. This plan shall
    reference relevant WBS/SOW elements where appropriate. MediWound will maintain and update the plan as necessary throughout the term of the contract and provide updates as requested by the COR. A report on these activities will be included as part of
    regular quarterly project status updates to the BARDA PO/CO.

   

  	WBS# and Title	Milestone	Deliverables
	1.1.3 Risk Management	Completion of risk management plan	Risk management plan submitted to BARDA


    

  Milestones:

   

  Completion of plan development stages as indicated above.

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 6 of 28


  

  

   

  
  
    	 


  

  
    	 


  

  
   

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

   

  Develop Risk Management Plan (WBS 1.1.3.1)

  Complete Risk Management Plan (WBS 1.1.3.2)

  Quarterly RMP Update (WBS 1.1.3.3)

   

  Deliverables:

   

  		-	Complete Risk Management Plan and Submit Report to BARDA (WBS 1.1.3.2)


  

  		-	Quarterly RMP Update Report to BARDA (WBS 1.1.3.3)


   

  		1.1.4	EVMS (WBS 1.1.4)


   

  	WBS# and Title	Milestone	Deliverables
	1.1.4 EVMS	Development and implementation of EVMS system.	Completion of EVMS system and regular EVMS reports to BARDA CO/PO.


    

  Objective/Description of Work: MediWound will use principles of Earned Value Management in the management of this contract and develop an EVMS plan as part of its deliverables.
    Documents maintained and utilized as part of MediWound’s EVMS will include: Integrated Master Schedule, Baseline Budget, WBS Dictionary, Control Account Work Authorization Documents, Control Account Plans, Baseline Logs and budget revision
    documentation, documentation required for the Performance Measurement Baseline Review (PMBR), and Monthly Earned Value Contract Performance Report (CPR).

   

  Milestones:

   

  Develop EVMS Plan Within 90 days of contract award. (WBS 1.1.4.1)

  Complete EVMS Plan Implementation Within 90 days of contract award. (WBS 1.1.4.3)

   

  Deliverables

   

  		-	EVMS System Implementation (WBS 1.1.4.2)


  

  		-	EVMS Monthly Report (WBS 1.1.4.4)


  

  		-	EVMS reports will be submitted on a monthly basis to the BARDA CO/PO commencing after the first report is delivered.


   

  		1.2	Non Clinical Toxicology (WBS 1.2)


   

  		1.2.1	Safety (WBS 1.2.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.2.1.1 [ * * * ]	
          [ * * * ]

           

        	Study report submitted to BARDA
	1.2.1.2 [ * * * ]	
          [ * * * ] 

          .

        	Study report submitted to BARDA
	1.2.1.3 [ * * * ]	
          [ * * * ]

            

          

        	Study report submitted to BARDA
	1.2.1.4 [ * * * ]	
          [ * * * ]

            

          

        	Study report submitted to BARDA
	1.2.1.5 [ * * * ]	
          [ * * * ]

           

        	Study report submitted to BARDA


   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 7 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
  

   

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

   

  		1.2.1.1	[ * * * ] (WBS 1.2.1.1)


   

  Objective/Description of Work: [ * * * ]

   

   

   

   

  

    .

   

   

  

  Milestones:

   

  [ * * * ] (WBS 1.2.1.1).

   

  Deliverables:

   

  		-	Study protocol for BARDA review and approval.


  

  		-	Final study report submitted to BARDA (WBS 1.2.1.1).


   

  

  		1.2.1.2	[ * * * ] (WBS 1.2.1.2)


   

  Objective/Description of Work: [ * * * ]

  

   

   

   

   

  .

   

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 8 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  

   

  	
          Advanced Development of NexoBrid

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

   

  	 	 


  

  Milestones:

   

  [ * * * ] (WBS 1.2.1.2).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.2.1.2).


  

  		-	Final study report submitted to BARDA (WBS 1.2.1.2).


   

  		1.2.1.3	[ * * * ] (WBS 1.2.1.3).


   

  Objective/Description of Work: [ * * * ]

   

  

  Milestones:

   

  [ * * * ] (WBS 1.2.1.3).

   

  

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.2.1.3).


  

  		-	Final study report submitted to BARDA (WBS 1.2.1.3).


   

  		1.2.1.4	[ * * * ] (WBS 1.2.1.4).


   

  Objective/Description of Work: [ * * * ]

   

     

  	MediWound Ltd. Confidential Information	Version 3.0	Page 9 of 28


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
     

  

  
     

  

  
   

  

  	
          Advanced Development of NexoBrid

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

   

  Milestones:

   

  [ * * * ] (WBS 1.2.1.4).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.2.1.4).


  

  		-	Final study report submitted to BARDA (WBS 1.2.1.4).


   

  		1.2.1.5	[ * * * ] (WBS 1.2.1.5).


   

  Objective/Description of Work:

   

  Milestones:

   

  [ * * * ] (WBS 1.2.1.5).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.2.1.5).


  

  		-	Final study report submitted to BARDA (WBS 1.2.1.5).


   

  		1.3	Non- Clinical Pharmacology (WBS 1.3)


   

  		1.3.1	Mechanism of Action Studies (WBS 1.3.1)


   

  	WBS# and Title	Milestone	Deliverables
	
          1.3.1.1 [ * * * ] 

           

        	
          [ * * * ]

          

            

            

            

            

            

            

          

        	Study reports submitted to BARDA
	1.3.1.2 [ * * * ]	[ * * * ]

          

          

          

          .	Study report submitted to BARDA
	1.3.1.3 [ * * * ]vitro	
          [ * * * ]

          

            

            

            

            

          

        	Study report submitted to BARDA
	1.3.1.4 [ * * * ]	
          [ * * * ]

          

            

            

            

            

            

            

          

        	Study report submitted to BARDA


   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 10 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
     

  

  
     

  

  
   

  	
          Advanced Development of NexoBrid

          as a Medical Countermeasure for Injury Associated with Burns

        	 


   

  		1.3.1.1	[ * * * ] (WBS 1.3.1.1)


   

  Objective/Description of Work: [ * * * ]

   

  Milestones:.

   

  Completion of study (WBS 1.3.1.1).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.3.1.1).


  

  		-	Final study report submitted to BARDA (WBS 1.3.1.1).


   

  		1.3.1.2	[ * * * ]

          (WBS 1.3.1.2).


   

  Objective/Description of Work: [ * * * ]

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 11 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
     

  

  
     

  

  
   

  	
          Advanced Development of NexoBrid

          as a Medical Countermeasure for Injury Associated with Burns

        	 


   

  Milestones:.

   

  Completion of study (WBS 1.3.1.2).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.3.1.2).


  

  		-	Final study report submitted to BARDA (WBS 1.3.1.2).


   

  		1.3.1.3	[ * * * ] (WBS 1.3.1.3)


   

  Objective/Description of Work: [ * * * ] 

  

   

  Milestones:.

   

  Completion of study (WBS 1.3.1.3).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.3.1.3).


  

  		-	Final study report submitted to BARDA (WBS 1.3.1.3).


   

  		1.3.1.4	[ * * * ] (WBS 1.3.1.4)


   

  Objective/Description of Work: [ * * * ]

  

   

  Milestones:.

   

  Completion of study (WSB 1.3.1.4).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.3.1.4).


   

  		-	Final study report submitted to BARDA (WBS 1.3.1.4).


   

   

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 12 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
     

  

  
     

  

  
   

  

  	Advanced Development of NexoBrid

              as a Medical Countermeasure for Injury Associated with Burns	 


  

   

  		1.3.2	Product Characterization (WBS 1.3.2)


   

  	WBS# and Title	Milestone	Deliverables
	1.3.2 [ * * * ]	[ * * * ]

          

          

          .	Study report submitted to BARDA


  

   

  		1.3.2.6	[ * * * ] (WBS 1.3.2.1)


   

  Objective/Description of Work: [ * * * ]

   

  Milestones:.

   

  Completion of study (WBS 1.3.2.1).

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.3.2.1).


  

  		-	Final study report submitted to BARDA (WBS 1.3.2.1).


   

  		1.3.3	Efficacy and Safety (WBS 1.3.3)


   

  		1.3.3.1	[ * * * ] (WBS 1.3.3.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.3.3.1 [ * * * ]	
          [ * * * ]

          

            

            

            

          

        	Study report submitted to BARDA


   

  Objective/Description of Work: [ * * * ]

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 13 of 28


  

   

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 	 	 


  

  
     

  

  
   

  	Advanced Development of NexoBrid

              as a Medical Countermeasure for Injury Associated with Burns	 


   

  Milestones:.

   

  Completion of study (WBS 1.3.3.1).

    

  Deliverables:

   

  		-	Study protocol for BARDA review/approval (WBS 1.3.3.1).


  

  		-	Final study report submitted to BARDA (WBS 1.3.3.1)


   

  		1.4	Clinical (WBS 1.4)


   

  		1.4.1	US phase 3 study (WBS 1.4.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.4.1  US phase 3 study	Completion of Phase 3 clinical trial.	Final clinical study report (CSR) accepted by BARDA.


   

  Objective/Description of Work: MediWound will complete a multicenter, multinational, randomized, controlled, assessor blinded phase 3 study in subjects with thermal burns, to
    evaluate the efficacy and safety of NexoBrid compared to Gel Vehicle and compared to Standard of Care. This study is currently ongoing.

   

  Study primary endpoint is to demonstrate superiority of NexoBrid over Gel Vehicle for eschar removal as measured by incidence of complete eschar removal. The following secondary endpoints
    will be evaluated in this study and compared between NexoBrid and SOC to further support the clinical benefit of NexoBrid.

   

  1.      Reduction in surgical need- Demonstrate superiority of NexoBrid over SOC in reduction of surgical need for excisional eschar removal as measured by an analysis of
    incidence of surgical eschar removal (tangential/ minor/ avulsion/ Versajet and/or dermabrasion excision).

   

  2.      Earlier eschar removal- Demonstrate superiority of NexoBrid over SOC with regard to the time when complete eschar removal has been achieved. For definition of complete
    eschar removal see primary endpoint.

   

  3.      Blood loss related to eschar removal- Demonstrate superiority of NexoBrid over SOC with regard to the blood loss occurred during the eschar removal procedures.

   

  This clinical trial is underway, however a study protocol will be provided to BARDA for reference. Any changes to the study protocol will be submitted to BARDA in advance for review.

   

  [ * * * ]

   

   

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 14 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 	 	 


  

  
     

  

  
    

  	Advanced Development of NexoBrid

              as a Medical Countermeasure for Injury Associated with Burns	 


   

  		•	[ * * * ]

          

          .


   

  		•	[ * * * ]

          

          

          

        


   

  		•	[ * * * ]

          

          

          

          

        


   

  175 Hospitalized adults with Deep Partial Thickness (DPT) and Full Thickness (FT) thermal burns will be enrolled. The total duration of the study treatment and follow up period of each
    participating subject is approximately 25 months. Approximately [ * * * ] sites will participate in the study from the US ([ * * * ]), Europe ([ * * * ]) and Israel and data will be monitored by local CROs from the US and Europe.

   

  Milestones

   

  First Patient In (WBS 1.4.1.1)

  

  Last Patient In (WBS 1.4.1.2)

  

  Last Patient Out (WBS 1.4.1.5)

   

  Deliverables:

   

  This study is currently on-going. Protocol amendments (if will be applied) will be provided to BARDA for review and approval before submission.

    

  [ * * * ] (WBS 1.4.1.3).

   

  [ * * * ]

  

   

   

  [ * * * ] (WBS 1.4.1.4).

   

  [ * * * ]

  

   

   

   

  [ * * * ] (WBS 1.4.1.6).

   

  [ * * * ]

  

   

   

   

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 15 of 28


    

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 	 	 


  

  
     

  

  
   

  	Advanced Development of NexoBrid

              as a Medical Countermeasure for Injury Associated with Burns	 


   

  		1.5	Regulatory


   

  		1.5.1	IND


   

  	WBS# and Title	Milestone	Deliverables
	1.5.1  IND	Completion of all pre-BLA activities in support of NexoBrid as an MCM.	[ * * * ]


   

  Objective/Description of Work: [ * * * ]

    

  

   

  		1.5.1.1	[ * * * ]

          (WBS 1.5.1.1)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  [ * * * ] (WBS 1.5.1.1).

   

  Deliverables:

   

  Final meeting minutes submitted to BARDA (WBS 1.5.1.1).

   

  		1.5.1.2	[ * * * ] (WBS 1.5.1.2)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  Completion of the FDA meeting (WBS 1.5.1.2).

   

  Deliverables:

   

  Final official meeting minutes submitted to BARDA (WBS 1.5.1.2).

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 16 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 	 	 


  

  
     

  

  
   

  

     

  	
          Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns 

        	 


  

     

  		1.5.1.3	[ * * * ] (WBS 1.5.1.3)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  Completion of the study protocol to FDA (WBS 1.5.1.3).

   

  Deliverables:

   

  Study protocol submitted to FDA for approval (WBS 1.5.1.3).

   

  		1.5.1.4	[ * * * ] (WBS 1.5.1.4)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  Completion of the study protocol after FDA guidance is received (WBS 1.5.1.4).

   

  Deliverables:

   

  		-	Prior to study initiation, the study protocol will be provided to BARDA for review and approval


  

  		-	Study protocol submitted to FDA for approval (WBS 1.5.1.4).


   

  		1.5.1.5	[ * * * ]

          (WBS 1.5.1.5)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  [ * * * ] (WBS 1.5.1.5).

   

  Deliverables:

   

  [ * * * ] (WBS 1.5.1.5).

  

    

  		1.5.1.6	FDA Submission Request For [ * * * ] (WBS 1.5.1.6)


   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 17 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns 

        	 


     

  Objective/Description of Work:

   

  In an attempt to expedite the development and review process of NexoBrid, MediWound plans to submit a request for [ * * * ] designation. Prior to submission, the [ * * * ] application
    request will be provided to BARDA for review and approval. 

   

   

   

  Milestones:

   

  Completion of the [ * * * ] application (WBS 1.5.1.6).

   

  Deliverables:

   

  [ * * * ] submitted to FDA for approval (WBS 1.5.1.6).

   

  		1.5.2	BLA (WBS 1.5.2)


   

  	WBS# and Title	Milestone	Deliverables
	1.5.2  BLA	Completion of all preparatory and regulatory activities for the BLA submission of NexoBrid as an MCM.	This includes all activities in support of the BLA submission.


     

  Objective/Description of Work: [ * * * ]

  

  

  

  		1.5.2.1	[ * * * ] (WBS 1.5.2.1)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  [ * * * ] (WBS 1.5.2.1).

   

  Deliverables:

   

  [ * * * ] (WBS 1.5.2.1).

   

  		1.5.2.2	Pre-BLA Meeting (WBS 1.5.2.2)


   

  Objective/Description of Work:

   

  [ * * * ]

   

   

   

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 18 of 28


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  

  
  
    	 


  

  
    	 


  

  
  

   

  	
          Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns 

        	 


  

   

  Milestones:

   

  Completion of FDA pre-BLA meeting (WBS 1.5.2.2).

   

  Deliverables:

   

  Final official meeting minutes submitted to BARDA (WBS 1.5.2.2).

   

  		1.5.2.3	BLA preparation and submission (WBS 1.5.2.3)


   

  Objective/Description of Work: [ * * * ]

  

   

  Milestones:

   

  BLA completion (WBS 1.5.2.3).

   

  Deliverables:

   

  [ * * * ] (WBS 1.5.2.3)

  

  [ * * * ] (US, PIP) (WBS 1.5.2.4)

  

  [ * * * ] (WBS 1.5.2.5)

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 19 of 28


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns 

        	 


    

   

  

  

  		1.6	Chemistry, Manufacturing and Control (CMC) (WBS 1.6)


   

  		1.6.1	[ * * * ] (WBS 1.6.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.6.1  [ * * * ]	[ * * * ]

          

          .	Reports submitted to BARDA CO/PO.


    

  		1.6.1.1	[ * * * ] (LC-MS) (WBS 1.6.1.1)


   

  Objective/Description of Work:

   

  [ * * * ]

    

  

  Milestones:

   

  [ * * * ] (WBS 1.6.1.1).

   

  Deliverables:

   

  Report on method submitted to BARDA PO/CO (WBS 1.6.1.1).

   

  		1.6.1.2	[ * * * ] (WBS 1.6.1.2)


   

  Objective/Description of Work:

   

  [ * * * ]

    

  

  Milestones:

   

  [ * * * ]

    (WBS 1.6.1.2).

   

  Deliverables:

   

  		-	Method validation protocol submitted to BARDA for review and approval.


   

  		-	Report on method submitted to BARDA PO/CO (WBS 1.6.1.2).


   

  		1.6.1.3	Analytical Support and Troubleshooting (WBS 1.6.1.3)


   

  MediWound will give analytical support and troubleshooting to the production processes of NexoBrid to ensure the quality of the product.

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 20 of 28


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
  

   

   

   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


   

  Deliverables:

   

  Report on support submitted to BARDA PO/CO (WBS 1.6.1.3).

     

  

  		1.6.2	[ * * * ] Development (WBS 1.6.2)


   

  	WBS# and Title	Milestone	Deliverables
	
          1.6.2.1 [ * * * ]

           

           

        	
          Completion of study to [ * * * ]

          

        	Final development  report submitted to BARDA
	
          1.6.2.2 [ * * * ]

           

          

            

          

        	Completion of study to [ * * * ]
           

        	[ * * * ]
	
          1.6.2.3 MediWound will conduct [ * * * ]

          

          

           

           

           

           

          

          

        	
          [ * * * ].

        	[ * * * ]
	
          1.6.2.4 [ * * * ]

          

            

          

        	[ * * * ].	[ * * * ]


   

   

  		1.6.2.1	NexoBrid [ * * * ] (WBS 1.6.2.1)


   

  Objective/Description of Work: [ * * * ]

  

  

   

  Milestones:

   

  [ * * * ] (WBS 1.6.2.1).

   

  Deliverables:

   

  		-	Study protocols will be provided to BARDA for review and approval.


   

  		-	Final development report submitted to BARDA (WBS 1.6.2.1).


   

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 21 of 28


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

   

  		1.6.2.2	[ * * * ] (WBS 1.6.2.2)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  Milestones:

   

  [ * * * ] (WBS 1.6.2.2).

   

  Deliverables:

   

  		-	Validation protocol will be provided to BARDA for review and approval.


   

  		-	Final process validation and stability reports (WBS 1.6.2.2).


   

  		1.6.2.3	[ * * * ] (WBS 1.6.2.3)


   

  Objective/Description of Work: [ * * * ]. 

  

  

  

  Milestones:

   

  [ * * * ] study completion (WBS 1.6.2.3).

   

  Deliverables:

   

  		-	[ * * * ].


   

  		-	Final study report (WBS 1.6.2.3).


   

  		1.6.2.4	[ * * * ] (WBS 1.6.2.4)


   

  Deliverables:

   

  [ * * * ] (WBS 1.6.2.4).

   

  		1.6.3	Quality by Design (QbD) (WBS 1.6.3)


   

  	WBS# and Title	Milestone	Deliverables
	1.6.3  Quality by Design	Completion of QbD studies defining the critical parameters and design space of the NexoBrid manufacturing
          process.	Reports submitted to BARDA CO/PO.


   

   

  		1.6.3.1	Risk Based Design of Experiment (DOE) Plan (WBS 1.6.3.1)


   

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 22 of 28


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


  

   

  Objective/Description of Work: MediWound will conduct together with [ * * * ] Ltd., or will assist other subcontractor approved by BARDA, risk based design of experiment (DOE) for
    creating a design space for the NexoBrid production process. [ * * * ]

    . The objective of the QbD research is to follow the FDA initiative of the Quality by Design approach. The QbD studies will follow the relevant ICH guidelines such as ICH Q8, ICH Q9 and Q10. QbD Studies protocol will be provided to BARDA for review and
    approval.

      

  Milestones:

   

  DOE study completion (WBS 1.6.3.1).

   

  Deliverables:

   

  		-	QbD Study protocol will be provided to BARDA for review and approval.


   

  		-	Final study report submitted to BARDA (WBS 1.6.3.1).


   

  		1.6.3.2	[ * * * ] (WBS 1.6.3.2)


   

  Objective/Description of Work: [ * * * ]

    

  

  Milestones:

   

  [ * * * ] (WBS 1.6.3.2).

   

  Deliverables:

   

  		-	Study protocol will be provided to BARDA for review and approval.


  

  		-	Final study report submitted to BARDA (WBS 1.6.3.2).


   

  		1.6.3.3	Statistical Analysis and Summary of the Results (WBS 1.6.3.3)


   

  Objective/Description of Work: [ * * * ]

   

  Milestones:

   

  [ * * * ] (WBS 1.6.3.3).

   

  Deliverables:

   

  		-	Final study report submitted to BARDA (WBS 1.6.3.3).


   

  		1.6.4	Agriculture Raw Material Studies (WBS 1.6.4)


   

   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 23 of 28


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


  

   

  	WBS# and Title	Milestone	Deliverables
	1.6.4 Agriculture Raw Material Studies	[ * * * ]	Reports submitted to BARDA CO/PO.


   

   

  		1.6.4.1	[ * * * ]

          (WBS 1.6.4.1)


   

  Objective/Description of Work: [ * * * ]

  

   

  Milestones:

   

  [ * * * ] (WBS 1.6.4.1).

   

  Deliverables:

   

  		-	Study protocols will be provided to BARDA for review and approval.


  

  		-	Final study report submitted to BARDA (WBS 1.6.4.1).


   

  		1.6.4.2	Analytical Chemistry Testing and Statistical Analysis (WBS 1.6.4.2)


   

  Objective/Description of Work: [ * * * ]

    

  

  Milestones:

   

  Study and analysis completion (WBS 1.6.4.2).

   

  Deliverables:

   

  		-	Study protocols will be provided to BARDA for review and approval.


   

  		-	Final study report submitted to BARDA (WBS 1.6.4.2).


   

  		1.6.5	[ * * * ] (WBS 1.6.5


   

  	WBS# and Title	Milestone	Deliverables
	1.6.5 [ * * * ]	[ * * * ]

          

          

          

          

           	Reports submitted to BARDA CO/PO; submissions sent to FDA for approval.


   

  

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 24 of 28 


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


  

   

  		1.6.5.1	[ * * * ] (WBS 1.6.5.1)


   

  Objective/Description of Work: [ * * * ]

    

  

  Milestones:

   

  Design completion (WBS 1.6.5.1).

   

  Deliverables:

   

  Final design submitted to BARDA (WBS 1.6.5.1).

   

  		1.6.5.2	[ * * * ] (WBS 1.6.5.2)


   

  		-	Objective/Description of Work: [ * * * ]


     

  Milestones:

   

  Validation/PQ activities completed (WBS 1.6.5.2).

   

  Deliverables:

   

  		-	Validation protocols will be provided to BARDA for review and approval.


  

  		-	Report on validation activities submitted to BARDA (WBS 1.6.5.2).


   

  		1.6.5.3	File Submission, Inspection & Approving (WBS 1.6.5.3)


   

  		-	Objective/Description of Work: [ * * * ]

          

          

          .


   

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 25 of 28 


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


  

   

  Milestones:

   

  Completion of submission preparation (WBS 1.6.5.3).

   

  Deliverables:

   

  [ * * * ] (WBS 1.6.5.3).

   

  		1.6.5.4	[ * * * ] (WBS 1.6.5.4)


   

  Objective/Description of Work: [ * * * ]

    

  

  Milestones:

   

  Completion of stability study (WBS 1.6.5.4).

      

  Deliverables:

   

  		-	Stability protocols for BARDA review and approval


  

  		-	Submission of stability report to BARDA and FDA (WBS 1.6.5.4).


   

  		1.6.5.5	FDA Approval of Scale-up (WBS 1.6.5.5)


   

  		-	Objective/Description of Work: [ * * * ]

          

        


   

  		-	. Application file will be provided to BARDA for review and approval prior to submission.


      

  Milestones:

   

  Completion of application for approval (WBS 1.6.5.5).

   

  Deliverables:

   

  Submission of application to BARDA and FDA (WBS 1.6.5.5).

   

   

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 26 of 28 


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


   

  		1.7	Procurement (WBS 1.7)


   

  		1.7.1	Acquisition (WBS 1.7.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.7.1 Acquisition	Acquisition of [ * * * ]of NexoBrid.	[ * * * ] of NexoBrid successfully delivered to BARDA.


   

   

  		1.7.2	Warm Base (Inventory Stockpile) (WBS 1.7.2)


   

  	WBS# and Title	Milestone	Deliverables
	1.7.2 Warm Base	Establishment of operational readiness to manufacture NexoBrid.	Report submitted to BARDA PO/CO.


   

   

  		1.7.2.1	Setup of vendor managed inventory system (VMI) plan (WBS 1.7.2.1)


   

  Objective/Description of Work: [ * * * ]

   

  Milestones:

   

  [ * * * ] and plan development (WBS 1.7.2.1).

   

  Deliverables:

   

  Submission of the VMI plan by BARDA (WBS 1.7.2.1).

   

  		1.7.2.2	Implementation of vendor managed inventory system (VMI) plan (WBS 1.7.2.2)


   

  Objective/Description of Work: MediWound will implement the VMI plan with the approved vendor.

   

  Milestones:

   

  Implementation of VMI plan (WBS 1.7.2.2).

   

  Deliverables:

   

  Notification to BARDA of successful implementation (WBS 1.7.2.2).

   

   

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 27 of 28 


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

   

  	Advanced Development of NexoBrid 

            as a Medical Countermeasure for Injury Associated with Burns	


  

   

  		1.7.3	Sustainment (WBS 1.7.3)


   

  	WBS# and Title	Milestone	Deliverables
	1.7.3 Sustainment	Replacement of expired material as necessary.	Replacement of expired material as necessary.


   

   

  		1.7.4	Disposal (WBS 1.7.4)


   

  	WBS# and Title	Milestone	Deliverables
	1.7.4 Disposal	Disposal of expired material as necessary.	Disposal of expired material as necessary.


   

   

  	MediWound Ltd. Confidential Information 	Version 3.0	 Page 28 of 28 


  

   

  
  
    	 


  

  
    	 


  

  
   

  

   

  

   

   

   

  Final Revised Proposal 

  Volume II: Technical Proposal

  Full Proposal Submitted for Consideration under Solicitation 15-100-SOL-00021

  Non-Surgical Debridement for Definitive Care of Burn Injuries

  This proposal is made in agreement with all the terms and conditions of this Solicitation.

    

  Advanced Development of NexoBrid  

  as a Medical Countermeasure for Injury Associated with Burns

   

  SOW Portion of the Options pages 89-98

   

  Submitted to: 

  Biomedical Advanced Research and Development Authority

  U.S. Department of Health and Human Services

  Assistant Secretary for Preparedness and Response

  Contracting Officer – Matthew Rose

  ASPR-AMCG-202-205-2901

  200 C St. SW

  Washington, D.C. 20024

  Attention: Matthew Rose, Contracting Officer

   

  	
          Reference: Solicitation # 15-100-SOL-00021

           

          Prime Offeror: 

           

          MediWound Ltd. 

          42 Hayarkon Street,

          Yavne, Israel 8122745

          Tel: + +972 77 9714100

          Fax: +972 77 9714111

          e-mail: 

            info@mediwound.cominfo@mediwound.com

          DUNS: 5320400334

           

          September 10, 2015

           

        	
           

           

          Business Contact:

           

          

          Gal Cohen 

          President & Chief Executive Officer

           

          Technical Contact: 

          Ety Klinger, PhD

          Chief R&D Officer

           

           

           

        


  

  

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


    

  Throughout this proposal, MediWound refers to various trademarks, service marks and trade names that it
        uses in its business. The “MediWound” design logo, “MediWound”, “NexoBrid”, “EscharEx” and other trademarks or service marks of MediWound appearing in this proposal are the property of MediWound. MediWound has several other trademarks, service
        marks and pending applications relating to its applications. Other trademarks and service marks appearing in this proposal are the property of their respective holders.

   

  TABLE OF CONTENTS

   

  	1.   Option Period Statement of Work (CLIN 0003, 0004, 0005)	3
	1.1   Program Management (WBS 1.1)	3
	1.1.1   Technical and Project Management (WBS 1.1.1)	3
	1.1.1.5   [ * * * ] / Report (WBS 1.1.1.5)	3
	1.1.1.6   [ * * * ] / Report (WBS 1.1.1.6)	3
	1.1.1.7   [ * * * ]/ Report (WBS 1.1.1.7)	3
	1.1.1.8   VMI Implementation Option Management (CLIN 0005A)/Report (WBS 1.1.1.8)	3
	1.4   Clinical (WBS 1.4)	3
	1.4.2   [ * * * ] (WBS 1.4.2)	3
	1.4.3   [ * * * ] (WBS 1.4.3)	6
	1.5   Regulatory	8
	1.5.3   Post Marketing Activities (WBS 1.5.3)	8
	1.5.3.1   Marketing Requirement- Infrastructure/Obligation (PhV, Call Center) (WBS 1.5.3.1)	8
	1.5.3.2   Phase IV Post-Marketing Study (WBS 1.5.3.2)	8
	1.5.3.3   [ * * * ] (WBS 1.5.3.3)	8
	1.6   Chemistry, Manufacturing and Control (CMC) (WBS 1.6)	10
	1.6.6   [ * * * ] (WBS 1.6.6)	10
	1.6.6.1   [ * * * ] (WBS 1.6.6.1)	10
	1.6.6.2   [ * * * ](WBS 1.6.6.2)	10
	1.6.6.3   File submission, Inspection & Approving (WBS 1.6.6.3)	10
	1.6.6.4   File submission, Inspection & Approving (WBS 1.6.6.4)	11
	1.6.6.5   File submission, Inspection & Approving (WBS 1.6.6.5)	11
	1.8   Surge Capacity (WBS 1.8)	12
	1.8.1   Acquisition (WBS 1.8.1)	12
	1.8.2   Warm Base (Inventory Stockpile) (WBS 1.8.2)	12
	1.8.3   Sustainment (WBS 1.8.3)	12
	1.8.4   Disposal (WBS 1.8.4)	12


   

  	MediWound Ltd. Confidential Information	Version 3.0	Page 2 of 12


  

   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


    

  

  		1.	Option Period Statement of Work (CLIN 0003, 0004, 0005)


   

  		1.1	Program Management (WBS 1.1)


   

  Updated SOW(s) and accompanying budgets will be provided to BARDA for each option period to define the
      execution of each CLIN.

   

  Program Management encompasses contract management (e.g., contract reporting), program management (e.g., subcontractor oversight,
      program progress), and risk management (e.g., EVM, risk evaluation). Project Management milestones and activities in this section are listed below, corresponding to management in the period described.

   

  		1.1.1	Technical and Project Management (WBS 1.1.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.1.1 Technical and
            Project Management	Successful completion of technical and project
            management activities for each option period.	Project scheduled completed and reports submitted to
            BARDA PO/CO after completion of each option period.


   

  Objective/Description of Work: These activities encompass all Program Management for the listed contract period.

   

  		1.1.1.5	[ * * * ] / Report (WBS 1.1.1.5)


   

  		1.1.1.6	[ * * * ] / Report (WBS 1.1.1.6)


   

  		1.1.1.7	Post-Marketing Option Management (CLIN 0003)/ Report (WBS 1.1.1.7)


   

  		1.1.1.8	VMI Implementation Option Management (CLIN 0005A)/Report (WBS 1.1.1.8)


   

  Objective/Description of Work: An overall project schedule in the form of a Gantt chart will be created and
      maintained as part of project management. This schedule will be updated and formally completed within 90 days after the contract award.

   

  Milestones:

   

  [ * * * ] / Report (WBS 1.1.1.5)

   

  Option 2 Management/ Report (WBS 1.1.1.6) 

  Option 3 Management/ Report (WBS 1.1.1.7)

  Option 4 Management/ Report (WBS 1.1.1.8)

   

  		1.4	Clinical (WBS 1.4)


   

  		1.4.2	[ * * * ] (WBS 1.4.2)


   

  	WBS# and Title	Milestone	Deliverables
	1.4.2 [ * * * ]	Completion of Phase 3 clinical trial	Final clinical study report (CSR) accepted by BARDA.


   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 3 of 12


    

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


    

  

  Objective/Description of Work: [ * * * ].

    

   

  [ * * * ]

    

     

  

  

  Milestones:

   

  First Patient In (WBS 1.4.2.1)

  Last Patient In (WBS 1.4.2.2)

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 4 of 12


    

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


    

  Last Patient Out (WBS 1.4.2.5)

   

  Deliverables:

   

  		-	Study protocol for BARDA review/approval prior to submission to FDA (WBS 1.4.2.1).


  

  		-	Safety analysis, [ * * * ] patient (WBS 1.4.2.3)


  

  		-	[ * * * ] month follow up: Data analysis + CSR (WBS 1.4.2.4)


  

  		-	[ * * * ] month follow up: Data analysis + CSR (WBS 1.4.2.6)


   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 5 of 12


    

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
  

   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


   

  		1.4.3	[ * * * ] (WBS 1.4.3)


   

  	WBS# and Title	Milestone	Deliverables
	1.4.3 [ * * * ]	Completion of Phase 3 clinical trial.	Final clinical study report (CSR) accepted by BARDA.


   

  This is a phase 3 study to assess NexoBrid effect on [ * * * ]. The main objective is to demonstrate the ability of NexoBrid to
      prevent and resolve [ * * * ]. The study will include approximately [ * * * ] patients from US sites and will be managed locally by a US CRO. The main endpoints will be [ * * * ].

    

   

  [ * * * ]

  

   

  

  

  Milestones:

   

  Set up (WBS 1.4.3.1) 

  First Patient In (WBS 1.4.3.2)

  Last Patient In (WBS 1.4.3.3)

  Last Patient Out (WBS 1.4.3.5)

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 6 of 12


    

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  	
          Advanced Development of NexoBrid 

          

          as a Medical Countermeasure for Injury Associated with Burns

        	 


    

  Deliverables:

   

  		-	Prior to study initiation, the study protocol will be provided to BARDA for review and approval. (WBS 1.4.3.1).


  

  		-	[ * * * ] (WBS 1.4.3.4)


  

  		-	[ * * * ] (WBS 1.4.3.6)


   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 7 of 12


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
  

  

   

  	Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns	 


   

  		1.5	Regulatory


   

  		1.5.3	Post Marketing Activities (WBS 1.5.3)


   

  	WBS# and Title	Milestone	Deliverables
	1.5.3  Post Marketing Activities	Initiation of FDA required post-marketing activities.	Successful establishment of required post-marketing activities.


   

  		1.5.3.1	Marketing Requirement- Infrastructure/Obligation (PhV, Call Center) (WBS 1.5.3.1)


   

  Objective/Description of Work:

   

  In order to comply with regulatory requirements for NexoBrid in the US market following approval, MediWound will establish an appropriate pharmacovigilance system, overseeing all safety
    aspects of the marketed product.

   

  Milestones:

   

  Establishment of the pharmacovigilance system in compliance with FDA guidance (WBS 1.5.3.1).

   

  Deliverables:

   

  Report on implemented pharmacovigilance system submitted to BARDA PO/CO (WBS 1.5.3.1).

   

  		1.5.3.2	Phase IV Post-Marketing Study (WBS 1.5.3.2)


   

  Objective/Description of Work:

   

  Following product approval, MediWound anticipates the necessity of conducting post approval activities (as was required in Europe by the EMA) that may or may not be required during the
    base period but may be required by the FDA. [ * * * ].

   

  Milestones:

   

  Initiation of post-approval marketing studies in compliance with FDA guidance (WBS 1.5.3.2).

   

  Deliverables:

   

  Report on implemented post-approval marketing studies submitted to BARDA PO/CO (WBS 1.5.3.2).

   

  		1.5.3.3	[ * * * ] (WBS 1.5.3.3)


   

  Objective/Description of Work:

   

  [ * * * ]

  

   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 8 of 12


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
   

  

  	Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns	 


  

   

  Milestones:

   

  Initiation of post-approval marketing studies in compliance with FDA guidance (WBS 1.5.3.3).

   

  Deliverables:

   

  		-	Study protocol will be provided to BARDA for review and approval.


  

  		-	Report on implemented post-approval marketing studies submitted to BARDA PO/CO (WBS 1.5.3.3).


   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 9 of 12


   

  

  
  
    	 


  

  
    	 


  

  
   

  

  	Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns	 


   

  		1.6	Chemistry, Manufacturing and Control (CMC) (WBS 1.6)


   

  		1.6.6	[ * * * ]

            (WBS 1.6.6)


   

  	WBS# and Title	Milestone	Deliverables
	1.6.6 1. [ * * * ]	[ * * * ]

          

          

          

          .	Reports submitted to BARDA CO/PO


   

  		1.6.6.1	[ * * * ] (WBS 1.6.6.1)


   

  		-	Objective/Description of Work: [ * * * ]

          

          

          .


    

  Milestones:

   

  Completion of application for approval (WBS 1.6.6.1).

   

  Deliverables:

   

  		-	Submission of design and technology transfer protocol and report to BARDA for review (WBS 1.6.6.1).


   

  		1.6.6.2	Subcontractor Facility technical batches and validations (WBS 1.6.6.2)


   

  Objective/Description of Work: [ * * * ]

    

  

  Milestones:

   

  Validation/PQ activities completed (WBS 1.6.6.2).

   

  Deliverables:

   

  Validation protocol and Report on validation activities submitted to BARDA (WBS 1.6.6.2).

   

  		1.6.6.3	File submission, Inspection & Approving (WBS 1.6.6.3)


   

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 10 of 12


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  	Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns	 


    

  Objective/Description of Work: MediWound will contract with consultants approved by BARDA, to prepare and submit a file of the [ * * * ]

  

   

  Milestones:

   

  Completion of submission preparation (WBS 1.6.6.3).

   

  Deliverables:

   

  [ * * * ] (WBS 1.6.6.3).

   

  		1.6.6.4	File submission, Inspection & Approving (WBS 1.6.6.4)


   

  Objective/Description of Work: MediWound will contract with consultants approved by BARDA to [ * * * ].

   

  Milestones:

   

  Completion of stability study (WBS 1.6.6.4).

   

  Deliverables:

   

  Submission of stability protocol and report to BARDA and FDA (WBS 1.6.6.4).

   

  		1.6.6.5	File submission, Inspection & Approving (WBS 1.6.6.5)


   

  Objective/Description of Work: [ * * * ]

  

   

  Milestones:

   

  Completion of application for approval (WBS 1.6.6.5).

   

  Deliverables:

   

  Submission of application to BARDA and FDA (WBS 1.6.6.5).

    

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 11 of 12


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  

  
  
    	 


  

  
    	 


  

  
   

  

  	Advanced Development of NexoBrid 

          as a Medical Countermeasure for Injury Associated with Burns	 


   

  		1.8	Surge Capacity (WBS 1.8)


   

  	WBS# and Title	Milestone	Deliverables
	1.8.1 Acquisition	Acquisition of up to [ * * * ] of NexoBrid.	[ * * * ] of NexoBrid successfully delivered to BARDA.
	1.8.2 Warm Base	Establishment of operational readiness to manufacture NexoBrid.	Report submitted to BARDA PO/CO.
	1.8.3 Sustainment	Replacement of expired material as necessary.	Replacement of expired material as necessary.
	1.8.4 Disposal	Disposal of expired material as necessary.	Disposal of expired material as necessary.


   

  		1.8.1	Acquisition (WBS 1.8.1)


   

  	WBS# and Title	Milestone	Deliverables
	1.8.1 Acquisition	Acquisition of [ * * * ] of NexoBrid. 	[ * * * ] of NexoBrid successfully delivered to BARDA.


   

  		1.8.2	Warm Base (Inventory Stockpile) (WBS 1.8.2)


   

  		1.8.3	Sustainment (WBS 1.8.3)


   

  		1.8.4	Disposal (WBS 1.8.4)


    

  

  	MediWound Ltd. Confidential Information	Version 3.0	Page 12 of 12


   

  [ * * * ] Certain identified information has been excluded from the exhibit because it is both (i) not material and (ii) would likely cause
    competitive harm to the registrant if publicly disclosed.

  
  
    	 


  

  
    	 


  

  
  

   

  

  

  

   

  	HHSO100201500035C	Mediwound Ltd


   

  ATTACHMENT #2

   

  INVOICE/FINANCING REQUEST INSTRUCTIONS - FOR COST-REIMBURSEMENT TYPE

      CONTRACTS

   

  Format: Payment requests shall be submitted on the Contractor’s self-generated form in the manner and format prescribed
      herein and as illustrated in the Sample Invoice/Financing Request. Standard Form 1034, Public Voucher for Purchases and Services Other Than Personal, may be used in lieu of the Contractor’s self-generated form provided it contains all of the
      information shown on the Sample Invoice/Financing Request. DO NOT include a cover letter with the payment request.

      Number of Copies: Payment requests shall be submitted in the quantity specified in the Invoice Submission Instructions in Section G of the Contract Schedule.

   

  Frequency: Payment requests shall not be submitted more frequently than once every two weeks in accordance with the
      Allowable Cost and Payment Clause incorporated into this contract. Small business concerns may submit invoices/financing requests more frequently than every two weeks when authorized by the Contracting Officer.

   

  Cost Incurrence Period: Costs incurred must be within the contract performance period or covered by pre-contract cost
      provisions.

   

  Billing of Costs Incurred: If billed costs include (1) costs of a prior billing period, but not previously billed, or (2)
      costs incurred during the contract period and claimed after the contract period has expired, the Contractor shall site the amount(s) and month(s) in which it incurred such costs.

   

  Contractor’s Fiscal Year: Payment requests shall be prepared in such a manner that the Government can identify costs
      claimed with the Contractor’s fiscal year.

   

  Currency: All BARDA contracts are expressed in United States dollars. When the Government pays in a currency other than
      United States dollars, billings shall be expressed, and payment by the Government shall be made, in that other currency at amounts coincident with actual costs incurred. Currency fluctuations may not be a basis of gain or loss to the Contractor.
      Notwithstanding the above, the total of all invoices paid under this contract may not exceed the United States dollars authorized.

   

  Costs Requiring Prior Approval: Costs requiring the Contracting Officer’s approval, including those set forth in an Advance
      Understanding in the contract, shall be identified and reference the Contracting Officer’s Authorization (COA) Number. In addition, the Contractor shall show any cost set forth in an Advance Understanding as a separate line item on the payment
      request.

   

  Invoice/Financing Request Identification: Each payment request shall be identified as either:

   

  	(a)	Interim Invoice/Contract Financing Request: These are interim payment requests submitted during the contract performance period.
	 	 
	(b)	Completion Invoice: The completion invoice shall be submitted promptly upon completion of the work, but no later than one year from the contract completion date, or within 120 days
            after settlement of the final indirect cost rates covering the year in which the contract is physically complete (whichever date is later). The Contractor shall submit the completion invoice when all costs have been assigned to the contract and
            it completes all performance provisions.
	 	 
	(c)	Final Invoice: A final invoice may be required after the amounts owed have been settled between the Government and the Contractor (e.g., resolution of all suspensions and audit
            exceptions).


   

  
  
     

  

  
     

  

  
   

  	HHSO100201500035C	Mediwound Ltd


   

  Preparation and Itemization of the Invoice/Financing Request: The Contractor shall furnish
        the information set forth in the instructions below. The instructions are keyed to the entries on the Sample Invoice/Financing Request.

   

  	(a)	Designated Billing Office Name and Address: Enter the designated billing office name and address, as identified in the Invoice Submission Instructions in
            Section G of the Contract Schedule.
	 	 
	(b)	Contractor’s Name, Address, Point of Contact, VIN, and DUNS or DUNS+4 Number: Show the Contractor’s name and address exactly as they appear in the contract, along with the name,
            title, phone number, and e-mail address of the person to notify in the event of an improper invoice or, in the case of payment by method other than Electronic Funds Transfer, to whom payment is to be sent. Provide the Contractor’s Vendor
            Identification Number (VIN), and Data Universal Numbering System (DUNS) number or DUNS+4. The DUNS number must identify the Contractor’s name and address exactly as stated on the face page of the contract. When an approved assignment has been
            made by the Contractor, or a different payee has been designated, provide the same information for the payee as is required for the Contractor (i.e., name, address, point of contact, VIN, and DUNS).
	 	 
	(c)	Invoice/Financing Request Number: Insert the appropriate serial number of the payment request.
	 	 
	(d)	Date Invoice/Financing Request Prepared: Insert the date the payment request is prepared.
	 	 
	(e)	Contract Number and Order Number (if applicable): Insert the contract number and order number (if applicable).
	 	 
	(f)	Effective Date: Insert the effective date of the contract or if billing under an order, the effective date of the order.
	 	 
	(g)	Total Estimated Cost of Contract/Order: Insert the total estimated cost of the contract, exclusive of fixed-fee. If billing under an order, insert the total estimated cost of the
            order, exclusive of fixed-fee. For incrementally funded contracts/orders, enter the amount currently obligated and available for payment.
	 	 
	(h)	Total Fixed-Fee: Insert the total fixed-fee (where applicable) or the portion of the fixed-fee applicable to a particular invoice as defined in the contract.
	 	 
	(i)	Two-Way/Three-Way Match: Identify whether payment is to be made using a two-way or three-way match. To determine required payment method, refer to the Invoice Submission
            Instructions in Section G of the Contract Schedule.
	 	 
	(j)	Office of Acquisitions: Insert the name of the Office of Acquisitions, as identified in the Invoice Submission Instructions in Section G of the Contract Schedule.
	 	 
	(k)	Central Point of Distribution: Insert the Central Point of Distribution, as identified in the Invoice Submission Instructions in Section G of the Contract Schedule.
	 	 
	(l)	Billing Period: Insert the beginning and ending dates (month, day, and year) of the period in which costs were incurred and for which reimbursement is claimed.
	 	 
	(m)	Amount Billed - Current Period: Insert the amount claimed for the current billing period by major cost element, including any adjustments and fixed-fee. If the Contract Schedule
            contains separately priced line items, identify the contract line item(s) on the payment request and include a separate breakdown (by major cost element) for each line item.


   

  
  
     

  

  
     

  

  
  

   

  	HHSO100201500035C	Mediwound Ltd


   

  	(n)	Amount Billed - Cumulative: Insert the cumulative amounts claimed by major cost element, including any adjustments and fixed-fee. If the Contract Schedule
            contains separately priced line items, identify the contract line item(s) on the payment request and include a separate breakdown (by major cost element) for each line item.
	 	 
	(o)	Direct Costs: Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.


  	 	 	 
	 	(1)	Direct Labor: Include salaries and wages paid (or accrued) for direct performance of the contract. List individuals by name, title/position, hourly/annual rate, level of effort
            (actual hours or % of effort), breakdown by task performed by personnel, and amount claimed.
	 	 	 
	 	(2)	Fringe Benefits: List any fringe benefits applicable to direct labor and billed as a direct cost. Do not include in this category fringe benefits that are included in indirect
            costs.
	 	 	 
	 	(3)	Accountable Personal Property: Include any property having a unit acquisition cost of $5,000 or more, with a life expectancy of more than two years, and sensitive property
            regardless of cost (see the HHS Contractor’s Guide for Control of Government Property)(e.g. personal computers). Note this is not permitted for reimbursement without pre-authorization from the CO.
	 	 	 
	 	 	On a separate sheet of paper attached to the payment request, list each item for which reimbursement is requested. Include reference to the following (as applicable):
	 	 	 
	 	 	- Item number for the specific piece of equipment listed in the Property Schedule, and
	 	 	 
	 	 	- COA number, if the equipment is not covered by the Property Schedule.
	 	 	 
	 	 	The Contracting Officer may require the Contractor to provide further itemization of property having specific limitations set forth in the contract.
	 	 	 
	 	(4)	Materials and Supplies: Include all consumable material and supplies regardless of amount. Detailed line-item breakdown (e.g. receipts, quotes, etc.) is required.
	 	 	 
	 	(5)	Premium Pay: List remuneration in excess of the basic hourly rate.
	 	 	 
	 	(6)	Consultant Fee: List fees paid to consultants. Identify consultant by name or category as set forth in the contract or COA, as well as the effort (i.e., number of hours, days,
            etc.) and rate billed.
	 	 	 
	 	(7)	Travel: Include domestic and foreign travel. Foreign travel is travel outside of Canada, the United States and its territories and possessions. However, for an organization located
            outside Canada, the United States and its territories and possessions, foreign travel means travel outside that country. Foreign travel must be billed separately from domestic travel.
	 	 	 
	 	(8)	Subcontract Costs: List subcontractor(s) by name and amount billed. Provide subcontract invoices/receipts as backup documentation. If subcontract is of the cost-reimbursement
            variety, detailed breakdown will be required. Regardless, include backup documentation (e.g. subcontractor invoices, quotes, etc.).


   

  
  
     

  

  
     

  

  
   

  	HHSO100201500035C	Mediwound Ltd


  

  	 	 	 
	 	(9)	Other: Include all other direct costs not fitting into an aforementioned category. If over $1,000, list cost elements and dollar amounts
            separately. If the contract contains restrictions on any cost element, that cost element must be listed separately.
	 	 	 


  	(p)	Cost of Money (COM): Cite the COM factor and base in effect during the time the cost was incurred and for which reimbursement is claimed, if applicable.
	 	 
	(q)	Indirect Costs: Identify the indirect cost base (IDC), indirect cost rate, and amount billed for each indirect cost category.
	 	 
	(r)	Fixed-Fee: Cite the formula or method of computation for fixed-fee, if applicable. The fixed-fee must be claimed as provided for by the contract.
	 	 
	(s)	Total Amounts Claimed: Insert the total amounts claimed for the current and cumulative periods.
	 	 
	(t)	Adjustments: Include amounts conceded by the Contractor, outstanding suspensions, and/or disapprovals subject to appeal.
	 	 
	(u)	Grand Totals
	 	 
	(v)	Certification of Salary Rate Limitation: If required by the contract (see Invoice Submission Instructions in Section G of the Contract Schedule), the Contractor shall include the
            following certification at the bottom of the payment request:
	 	 
	 	“I hereby certify that the salaries billed in this payment request are in compliance with the Salary Rate Limitation Provisions in Section H of the contract.”
	 	 
	**Note the Contracting Officer may require the Contractor to submit detailed support for costs claimed on payment requests. Every cost must be determined to be allocable,
            reasonable, and allowable per FAR Part 31.


   

  

  
  
     

  

  
     

  

  
   

  	HHSO100201500035C	Mediwound Ltd


   

  ATTACHMENT #3

   

  INVOICE/FINANCING REQUEST INSTRUCTIONS FOR FIXED PRICE TYPE CONTRACTS

   

  General The Contractor shall submit vouchers or invoices as prescribed herein.

   

  Format Standard Form I034, Public Voucher for Purchases and Services Other Than Personal, and Standard Form I035, Public
      Voucher for Purchases and Services Other than Personal--Continuation Sheet, and the payee’s letterhead or self-designed form should be used to submit claims for reimbursement.

   

  Number of Copies: As indicated in the contract.

   

  Frequency Invoices submitted in accordance with the Payment Clause shall be submitted monthly upon delivery of goods or
      services unless otherwise authorized by the Contracting Officer.

   

  Preparation and Itemization of the Invoice The invoice shall be prepared as follows:

   

  (a) Designated Billing Office and address:

   

  HHS/ASPR/BARDA

   

  330 Independence Ave, Room G640 

    

   

  Washington DC 20201 

    

   

  ATTN: Contracting Officer

   

  (b) Invoice Number

   

  (c) Date of Invoice

   

  (d) Contract number and date

   

  (e) Payee’s name and address. Show the Contractor’s name (as it appears in the contract), correct address, and the title and phone
      number of the responsible official to whom payment is to be sent. When an approved assignment has been made by the Contractor, or a different payee has been designated, then insert the name and address of the payee instead of the Contractor.

   

  (f) Description of goods or services, quantity, unit price, (where appropriate), and total amount.

   

  (g) Charges for freight or express shipments other than F.O.B. destination. (If shipped by freight or express and charges are more
      than $25, attach prepaid bill.)

   

  (h) Equipment - If there is a contract clause authorizing the purchase of any item of equipment, the final invoice must contain a
      statement indicating that no item of equipment was purchased or include a completed form HHS-565, Report of Capitalized Nonexpendable Equipment.

   

  Currency: Where payments are made in a currency other than United States dollars, billings on the contract shall be
      expressed, and payment by the United States Government shall be made, in that other currency at amounts coincident with actual costs incurred. Currency fluctuations may not be a basis of gain or loss to the Contractor. Notwithstanding the above, the
      total of all invoices paid under this contract may not exceed the United States dollars authorized.

   

  
  
     

  

  
     

  

  
  

   

  

  

  

   

  	HHSO100201500035C	Mediwound Ltd


  ATTACHMENT #4 - SAMPLE INVOICE FORM

  Company Name

  	Designated Billing Office Name and Address:	Invoice/Finance Number:
	 	 
	DHHS/OS/ASPR/AMCG	Date Invoice Prepared:
	Attn: Contracting Officer	 
	200 C St., S.W.	Contract No. and Title:
	 	 
	Washington, D.C. 20201	Effective Date & Period of Performance:
	 	 
	Contractor’s Address and Contact Information:	Total Estimated Cost of Order:
	 	 
	 	Office of Acquisitions:
	 	Contracting Officer (insert name here)
	 	Office of Acquisitions Management, Contracts, and
	POC: Name of accountant or COO or signatory authority for invoice	Grants (AMCG)
	Title:	 
	Phone:	 
	E-Mail:	Central Point of Distribution:
	 	 
	TIN:	 
	DUNS #:	 


  

  

  	This invoice represents reimbursable costs for the period from	
	Expenditure


              Category	Amount Billed	 
	Current	Cumulative	Contract Value
	Direct Costs:	 	 	 
	Direct Labor	 	 	 
	Fringe Benefits               0.00%	 	 	 
	Total Labor Costs:	 	 	 
	 	 	 	 
	Overhead                                    0.00%	 	 	 
	 	 	 	 
	Travel	 	 	 
	Subcontracts	 	 	 
	Consultant Fees	 	 	 
	Materials and Supplies	 	 	 
	Other	 	 	 
	Total Direct Costs	 	 	 
	 	 	 	 
	G&A Rate                                    0.00%	 	 	 
	 	 	 	 
	Subtotal:	 	 	 
	 	 	 	 
	Fixed Fee                                       0.0	 	 	 
	 	 	 	 
	Total Amount Claimed	 	 	 
	 	 	 	 
	Adjustments	 	 	 
	 	 	 	 
	Grand Total	$	—	 	 


  I certify that all payments requested are for appropriate purposes and in accordance with the
      contract.

   

  
  
     

  

  
  Name/signature of signatory authority for invoicing

   

  
  
    	 


  

  
    	 


  

  
   

  	HHSO100201500035C	Mediwound Ltd


  

  ATTACHMENT #5 

  RESEARCH PATIENT CARE COSTS

  		(a)	Research patient care costs are the costs of routine and ancillary services provided to patients participating in research programs described in this contract.


  		(b)	Patient care costs shall be computed in a manner consistent with the principles and procedures used by the Medicare Program for determining the part of Medicare reimbursement based on
            reasonable costs. The Diagnostic Related Group (DRG) prospective reimbursement method used to determine the remaining portion of Medicare reimbursement shall not be used to determine patient care costs. Patient care rates or amounts shall be
            established by the Secretary of HHS or his duly authorized representative.


  		(c)	Prior to submitting an invoice for patient care costs under this contract, the Contractor must make every reasonable effort to obtain third party payment,
            where third party payors (including Government agencies) are authorized or are under a legal obligation to pay all or a portion of the charges incurred under this contract for patient care.


  		(d)	The Contractor must maintain adequate procedures to identify those research patients participating in this contract who are eligible for third party reimbursement.


  		(e)	Only those charges not recoverable from third party payors or patients and which are consistent with the terms and conditions of the contract are chargeable to this contract.


  

  
  
    	 


  

  
    	 


  

  
   

  Attachment 6

   

  	REPORT OF GOVERNMENT OWNED, CONTRACTOR HELD PROPERTY
	CONTRACTOR:	
           CONTRACT NUMBER:

           

        
	ADDRESS:	REPORT DATE:
	ADDRESS1:	 
	ADDRESS2:	FISCAL YEAR:
	CITY:	 
	STATE:
	ZIP:	 	 	 
	CLASSIFICATION	BEGINNING OF 

            PERIOD	ADJUSTMENTS	END OF PERIOD
	 	#ITEMS	VALUE	GFP 

            ADDED	CAP 

            ADDED	DELETIONS	#ITEMS	VALUE
	LAND


            >=$25K	 	 	 	 	 	 	 
	LAND


            <$25K	 	 	 	 	 	 	 
	OTHER


            REAL >=$25K	 	 	 	 	 	 	 
	OTHER


            REAL <$25K	 	 	 	 	 	 	 
	PROPERTY UNDER CONST >=$25K	 	 	 	 	 	 	 
	PROPERTY UNDER CONST <$25K	 	 	 	 	 	 	 
	PLANT


            EQUIP >=$25K	 	 	 	 	 	 	 
	PLANT


            EQUIP <$25K	 	 	 	 	 	 	 
	SPECIAL


            TOOLING >=$25K	 	 	 	 	 	 	 
	SPECIAL


            TOOLING <$25K	 	 	 	 	 	 	 
	SPECIAL


            TEST EQUIP >=$25K	 	 	 	 	 	 	 
	SPECIAL


            TEST EQUIP <$25K	 	 	 	 	 	 	 
	AGENCY


            PECULIAR >=$25K	 	 	 	 	 	 	 
	AGENCY


            PECULIAR <$25K	 	 	 	 	 	 	 
	MATERIAL >=$25K (CUMULATIVE)	 	 	 	 	 	 
	PROPERTY UNDER MFR >=$25K	 	 	 	 	 	 	 
	PROPERTY UNDER MFR <$25K	 	 	 	 	 	 	 
	SIGNED BY:	 	 	 
	
           SIGNATURE

        		DATE SIGNED:	
           

           

           

        
	
           

          NAME PRINTED

        	 	
           

          Email

           

        	 
	
           

          TITLE

        	 	
           

          

          TELEPHONE

           

        	 
	 	 	 	 	 	 	 	 	 	 	 	 	 	 


  Report of Government Owned, Contractor Held Property (Rev 10/2014)

   

  
  
    	 


  

  
    	 


  

  
  	
           

          Attachment 7 

            DISCLOSURE OF LOBBYING ACTIVITIES

          Complete this form to disclose lobbying activities pursuant
              to 31 U.S.C. 1352 

              (See reverse for public burden disclosure.)

        	Approved by OMB 

            0348-0046


   

  	1. Type of Federal
              Action:	2. Status of Federal Action:                 	3. Report Type:
	
           ☐  a. contract

                  b. grant

                  c. cooperative agreement

                  d. loan

                  e. loan guarantee

                  f. loan insurance

        	
                  ☐ a. bid/offer/application

                         b. initial award

                         c. post-award

           

        	
               ☐  a.  initial filing

                       b. material change

                For Material Change Only:

                        year _______ quarter __________

                        date of last report _____________

        


  	
          4. Name and Address of Reporting Entity:

                 ☐ Prime              ☐ Subawardee

                                             Tier _______, if known:

           

          

                  Congressional District, if known: 4c

        	
          5. If Reporting Entity in No. 4 is a Subawardee, Enter Name and Address of Prime:

           

           

           

           

           

           

              Congressional District, if known:

        
	6. Federal
              Department/Agency:	
          7. Federal Program Name/Description:

           

              CFDA Number, if applicable:____________

           

        
	8. Federal Action Number,
            if known:	
          9. Award Amount, if known:

              $

        
	
          10. a. Name and Address of Lobbying Registrant

                  (if individual, last name, first name, Ml):

           

        	b. Individuals Performing Services
            (including address if different from No. 10a) 

              (last name, first name, Ml):
	
          11.  Information requested through this form is authorized by title 31 U.S.C. section 1352. This disclosure of lobbying activities is a material representation of fact upon which reliance was
              placed by the tier above when this transaction was made or entered into. This disclosure is required pursuant to 31 U.S.C. 1352. This information will be available for public inspection. Any person who fails to file the required
              disclosure shall be subject to a civil penalty of not less than $10, 000 and not more than $100,000 for each such failure. 

          

        	
          

          Signature:___________________________________________________________________

           

          Print Name:_________________________________________________________________

           

          Title:_______________________________________________________________________

           

          Telephone No.:______________________________________________ Date:____________

          

        


  	Federal Use Only:	Authorized for Local Reproduction 

            Standard Form LLL (Rev. 7-97)


   

   

  
  
    	 


  

  
    	 


  

  
   

  

  

   

  INSTRUCTIONS FOR COMPLETION OF SF-LLL, DISCLOSURE OF LOBBYING ACTIVITIES

   

  This disclosure form shall be completed by the reporting entity, whether subawardee or prime Federal
      recipient, at the initiation or receipt of a covered Federal action, or a material change to a previous filing, pursuant to title 31 U.S.C. section 1352. The filing of a form is required for each payment or agreement to make payment to any lobbying
      entity for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of Congress, or an employee of a Member of Congress in connection with a covered Federal action. Complete all items
      that apply for both the initial filing and material change report. Refer to the implementing guidance published by the Office of Management and Budget for additional information.

   

  	 	1.	Identify the type of covered Federal action for which lobbying activity is and/or has been secured to influence the outcome of a covered Federal
            action.
	 	 	 
	 	2.	Identify the status of the covered Federal action.
	 	 	 
	 	3.	Identify the appropriate classification of this report. If this is a followup report caused by a material change to the information previously
            reported, enter the year and quarter in which the change occurred. Enter the date of the last previously submitted report by this reporting entity for this covered Federal action.
	 	 	 
	 	4.	Enter the full name, address, city, State and zip code of the reporting entity. Include Congressional District, if known. Check the appropriate
            classification of the reporting entity that designates if it is, or expects to be, a prime or subaward recipient. Identify the tier of the subawardee, e.g., the first subawardee of the prime is the 1st tier. Subawards include but are not
            limited to subcontracts, subgrants and contract awards under grants.
	 	 	 
	 	5.	If the organization filing the report in item 4 checks “Subawardee,” then enter the full name, address, city, State and zip code of the prime
            Federal recipient. Include Congressional District, if known.
	 	 	 
	 	6.	Enter the name of the Federal agency making the award or loan commitment. Include at least one organizational level below agency name, if known.
            For example, Department of Transportation, United States Coast Guard.
	 	 	 
	 	7.	Enter the Federal program name or description for the covered Federal action (item 1). If known, enter the full Catalog of Federal Domestic
            Assistance (CFDA) number for grants, cooperative agreements, loans, and loan commitments.
	 	 	 
	 	8.	Enter the most appropriate Federal identifying number available for the Federal action identified in item 1 (e.g., Request for Proposal (RFP)
            number; Invitation for Bid (IFB) number; grant announcement number; the contract, grant, or loan award number; the application/proposal control number assigned by the Federal agency). Include prefixes, e.g., “RFP-DE-90-001.”
	 	 	 
	 	9.	For a covered Federal action where there has been an award or loan commitment by the Federal agency, enter the Federal amount of the award/loan
            commitment for the prime entity identified in item 4 or 5.
	 	 	 
	 	10.	(a) 	Enter the full name, address, city, State and zip code of the lobbying registrant under the Lobbying Disclosure Act of 1995 engaged by the
            reporting entity identified in item 4 to influence the covered Federal action.
	 	 	 	 
	 	 	(b)	Enter the full names of the individual(s) performing services, and include full address if different from 10 (a). Enter Last Name, First Name, and Middle
            Initial (Ml).
	 	 	 	 
	 	11.	The certifying official shall sign and date the form, print his/her name, title, and telephone number.
	 	 	 	 


  

  	According to the Paperwork Reduction Act, as amended, no persons are required to respond to a
            collection of information unless it displays a valid OMB Control Number. The valid OMB control number for this information collection is OMB No. 0348-0046. Public reporting burden for this collection of information is estimated to average 10
            minutes per response, including time for reviewing instructions, searching existing data sources, gathering and maintaining the data needed, and completing and reviewing the collection of information. Send comments regarding the burden estimate
            or any other aspect of this collection of information, including suggestions for reducing this burden, to the Office of Management and Budget, Paperwork Reduction Project (0348-0046), Washington, DC 20503.


   

  
  
     

  

  
     

  

  
  

   

  Cumulative Inclusion Enrollment Report

   

  This report format should NOT be used for collecting data from study participants.

   

  Study Title:

   

  Comments:

   

  	Racial


              Categories	Ethnic Categories	Total
	Not
              Hispanic or Latino	Hispanic or Latino	Unknown/Not Reported Ethnicity
	Female	Male	Unknown/

            Not

            Reported	Female	Male	Unknown/

            Not

            Reported	Female	Male	Unknown/

            Not

            Reported
	American Indian/ Alaska Native	 	 	 	 	 	 	 	 	 	0
	Asian	 	 	 	 	 	 	 	 	 	0
	Native Hawaiian or Other Pacific Islander	 	 	 	 	 	 	 	 	 	0
	Black or African American	 	 	 	 	 	 	 	 	 	0
	White	 	 	 	 	 	 	 	 	 	0
	More Than One Race	 	 	 	 	 	 	 	 	 	0
	Unknown or Not Reported	 	 	 	 	 	 	 	 	 	0
	Total	0	0	0	0	0	0	0	0	0	0


   

  	PHS 398 / PHS 2590 (Rev. 08/12 Approved Through 8/31/2015)	 	OMB No. 0925-0001/0002
	 		Cumulative Inclusion Enrollment Report