Exhibit 4.17




---



##### 



Supplementary Agreement (II)
  Supplemental Agreement (II) of
 Main Contractors Works Contract
       1
    
    The Supplemental Agreement is supplemental to the Main Contractors Works Contract entered
into by and between the Employer and the Main Contractor on 28th March, 2008
(hereinafter referred to the Main Contract) by which the Employer assigned the Main
Contractor to implement and complete the main contractors works known as Zastron Wuxi
Flexible Printed Circuit (FPC) Factory (hereinafter referred to the Works).2
    
    Thereafter, the Employer and the Main Contractor entered into a Supplemental Agreement (I) of
the Main Contract on 10th July, 2008, assigning the Electrical Engineering Works to
the Main Contractor to implement and complete (hereinafter referred to the Electrical
Engineering Works).
 
 1




---



##### 



Supplementary Agreement (II)
 3
    
    Because of the delay in the Works, the Works could not be completed pursuant to the
completion date as stipulated in the Main Contract. Both Parties disagreed on the practical
completion date and could not agree on the compensation arising from the delay in the Works.
Furthermore, both parties wish to confirm the final total price of the Works (except Specified
Subcontract Works) in the hope to resolve all the aforesaid issues.
  (1)
    
    Final Total Price of the Main Contract (except Specified Subcontract Works)The Final Total Price of the Main Contract (except Specified Subcontract Works) comprises the
following:
 RMBPrice of the Main Contract (except
Specified Subcontract Works) (see Appendix (II))
    
    
    207,000,000.00Minus Compensation for delay in works (see Appendix (III))
    
    
    (6,000,000.00
    )Final Total Price of the Main Contract
    
    
    201,000,000.00
 Main Contractor confirms that the aforesaid price is the Final Total Price of the Main
Contract (except Specified Subcontract Works), and agrees that it will not ask for any
other additional compensation. Main Contractor further confirms that it will be
responsible for any legal liabilities arising out of any destructions, damages on
destructions, losses, claims or litigations related to the Work.(2)
    
    Practical Completion DateBoth Parties agree that the practical completion date of the Works is April 30th,
2009 (see the Practical Completion Certificate in Appendix (I) as issued by the
Project Manager).
 
 2




---



##### 



Supplementary Agreement (II)
 (3)
    
    Project List of Defects WorksAfter this Supplemental Agreement has been signed, both Parties agreed that out of the total
sum to be payable to the Main Contractor, a sum of RMB2,000,000.00 shall be temporarily
withheld, and the Main Contractor shall within 30 calendar days complete the works to rectify
the defects as mentioned in the list affixed to the Practical Completion Certificate. When
the aforesaid works to rectify the defects have all been completed and certified duly
completed, the Employer agrees to pay such RMB2,000,000.00 to the Main Contractor within 30
calendar days thereafter.(4)
    
    Payment arrangements for the remainder of the Price being the Final Total Price minus the
payment already made (hereinafter referred to Remainder of the Price)After this Supplemental Agreement has been signed by both Parties, the Remainder of the Price
shall be paid as follows:
 a.
    
    The Employer shall within 7 calendar days pay to the Main Contractor the amounts
as specified in the 13th and 15th mid term payment certificate.b.
    
    The Employer shall within 30 calendar days return to the Main Contractor the
amount of the performance bond (in the amount of RMB20,766,000.00).c.
    
    Except half of the warranty fund withheld pursuant to the conditions of the Main
Contract (i.e. RMB5,191,500.00) and the moneys withheld pursuant to clause 3 of this
Supplemental Agreement (i.e. RMB2,000,000.00), the Employer shall within 30 calendar
days pay to the Main Contractor the remainder of the payment.d.
    
    The remaining warranty fund shall be paid pursuant to the terms of the Main
Contract after the expiry of the Warranty Period or the responsibility regarding
maintenance has been completed.
 (5)
    
    InterpretationUnless expressly stipulated in this Supplemental Agreement, the obligations, duties and
responsibilities undertaken by the Employer and the Main Contractor in accordance with the
Main Contract and the Supplemental Agreement (I) shall remain unchanged and shall be
applicable to the execution of this Supplemental Agreement. Where any variances or
contradictions between this Supplemental Agreement and the contents of the Main Contract and
the Supplemental Agreement (I) exist, the meaning of the express provisions of this
Supplemental Agreement shall take precedence.
 
 3




---



##### 



Supplementary Agreement (II)
 (6)
    
    ArbitrationAny disputes incurred by or related to the Supplemental Agreement shall be submitted to China
International Economic and Trade Arbitration Commission Shanghai Sub-Commission, and shall be
arbitrated in Shanghai in accordance with the existing and valid arbitration rules of the
Commission. The arbitration decision shall be the final judgment and binding on both parties.(7)
    
    AppendicesThis Supplemental Agreement comprises the following appendices which are an integral part of
this Supplemental Agreement:
 Appendix (I):
    
    Practical Completion CertificateAppendix (II):
    
    Total Final Price for the Works (except Specified Subcontract Works)Appendix (III):
    
    Compensation for Delay in Works
 
 4




---



##### 



Supplementary Agreement (II)
   Employer: Zastron Precision-Flex (Wuxi) Co., Ltd.By Statutory 
Representative or 
Authorized 
Representative
    
    (Signature)
Date: 26th July, 2009
    
    Seal:(Seal of
Zastron
Precision-Flex
(Wuxi) Co., Ltd.)By the Witness
    
    (Signature)
Date: 26th July, 2009
 Main Contractor: Yixing Building Engineering & Installation Co., Ltd.By Statutory 
Representative or 
Authorized 
Representative
    
    (Signature)
Date: 24th July, 2009
    
    Seal:(Seal of
Yixing Building
Engineering &
Installation Co.,
Ltd.)By the Witness
    
    (Signature)
Date: 24th July, 2009
 
 5