EXHIBIT 10.49

WESTLAKE PARK PLACE

LEASE AGREEMENT

between

WESTLAKE PLAZA CENTER EAST, LLC,

as Landlord,

and

FIRST CALIFORNIA BANK,

as Tenant

Dated: November 23, 2007







---

TABLE OF CONTENTS



|   |  |                                                              |  |                                        |  |     
|-- |  | ------------------------------------------------------------ |  | -------------------------------------- |  | ----
|   |  |                                                              |  |                                        |  | Page
|1. |  | BASIC LEASE DEFINITIONS, EXHIBITS AND ADDITIONAL DEFINITIONS |  | 1                                     
|   |  | 1.1                                                          |  | Basic Lease Definitions                |  | 1   
|   |  | 1.2                                                          |  | Exhibits and Riders                    |  | 5   
|   |  | 1.3                                                          |  | Additional Definitions                 |  | 5   
|   |  |                                                             
|2. |  | GRANT OF LEASE                                               |  | 8                                     
|   |  | 2.1                                                          |  | Demise                                 |  | 8   
|   |  | 2.2                                                          |  | Common Areas                           |  | 8   
|   |  | 2.3                                                          |  | Landlords Reserved Rights             |  | 9   
|   |  |                                                             
|3. |  | RENT                                                         |  | 9                                     
|   |  | 3.1                                                          |  | Base Rent                              |  | 9   
|   |  | 3.2                                                          |  | Additional Rent                        |  | 9   
|   |  | 3.3                                                          |  | Excess Expenses                        |  | 9   
|   |  | 3.4                                                          |  | Estimate Statement                     |  | 9   
|   |  | 3.5                                                          |  | Actual Statement                       |  | 10  
|   |  | 3.6                                                          |  | No Release                             |  | 10  
|   |  | 3.7                                                          |  | Other Taxes                            |  | 10  
|   |  | 3.8                                                          |  | Terms of Payment                       |  | 10  
|   |  | 3.9                                                          |  | Right to Accept Payments               |  | 10  
|   |  | 3.10                                                         |  | Audit Rights                           |  | 11  
|   |  |                                                             
|4. |  | USE AND OCCUPANCY                                            |  | 11                                    
|   |  | 4.1                                                          |  | Use                                    |  | 11  
|   |  | 4.2                                                          |  | Compliance                             |  | 11  
|   |  | 4.3                                                          |  | Occupancy                              |  | 11  
|   |  | 4.4                                                          |  | Hazardous Material                     |  | 12  
|   |  |                                                             
|5. |  | SERVICES AND UTILITIES                                       |  | 14                                    
|   |  | 5.1                                                          |  | Landlords Standard Services           |  | 14  
|   |  | 5.2                                                          |  | Tenants Obligations                   |  | 16  
|   |  | 5.3                                                          |  | Interruption of Services               |  | 16  
|   |  | 5.4                                                          |  | Security                               |  | 16  
|   |  |                                                             
|6. |  | REPAIRS                                                      |  | 17                                    
|   |  | 6.1                                                          |  | Condition of Premises                  |  | 17  
|   |  | 6.2                                                          |  | Tenants Repair and Notice Obligations |  | 17  
|   |  | 6.3                                                          |  | Landlords Repair Obligations          |  | 17  
|   |  | 6.4                                                          |  | Failure to Maintain Premises           |  | 18  
|   |  | 6.5                                                          |  | Tenants Repair Rights                 |  | 18  
|   |  |                                                             
|7. |  | ALTERATIONS                                                  |  | 19                                    
|   |  | 7.1                                                          |  | Tenant Changes; Conditions             |  | 19  
|   |  | 7.2                                                          |  | Tenants Failure to Remove             |  | 20  
|   |  | 7.3                                                          |  | Alterations by Landlord                |  | 21  
|   |  |                                                             
|8. |  | LIENS                                                        |  | 21                                    
|   |  |                                                             
|9. |  | INSURANCE                                                    |  | 21                                    
|   |  | 9.1                                                          |  | Landlords Insurance                   |  | 21  
|   |  | 9.2                                                          |  | Tenants Insurance                     |  | 22  
|   |  | 9.3                                                          |  | Waiver of Subrogation                  |  | 24  



i



---

TABLE OF CONTENTS

(continued)



|    |  |                                  |  |                                            |  |     
|--- |  | -------------------------------- |  | ------------------------------------------ |  | ----
|    |  |                                  |  |                                            |  | Page
|10. |  | DAMAGE OR DESTRUCTION            |  | 25                                        
|    |  | 10.1                             |  | Landlords Rights and Obligations          |  | 25  
|    |  | 10.2                             |  | Tenants Costs and Insurance Proceeds      |  | 25  
|    |  | 10.3                             |  | Abatement of Rent                          |  | 25  
|    |  | 10.4                             |  | Inability to Complete                      |  | 26  
|    |  | 10.5                             |  | Damage Near End of Term                    |  | 26  
|    |  | 10.6                             |  | Waiver of Other Termination Rights         |  | 26  
|    |  |                                 
|11. |  | WAIVERS AND INDEMNITIES          |  | 26                                        
|    |  | 11.1                             |  | Tenants Waivers                           |  | 26  
|    |  | 11.2                             |  | Landlords Indemnity                       |  | 27  
|    |  | 11.3                             |  | Tenants Indemnity                         |  | 27  
|    |  |                                 
|12. |  | CONDEMNATION                     |  | 27                                        
|    |  | 12.1                             |  | Full Taking                                |  | 27  
|    |  | 12.2                             |  | Partial Taking                             |  | 27  
|    |  | 12.3                             |  | Awards                                     |  | 28  
|    |  |                                 
|13. |  | ASSIGNMENT AND SUBLETTING        |  | 28                                        
|    |  | 13.1                             |  | General                                    |  | 28  
|    |  | 13.2                             |  | Restriction on Transfer                    |  | 28  
|    |  | 13.3                             |  | Landlords Options                         |  | 28  
|    |  | 13.5                             |  | Reasonable Disapproval                     |  | 29  
|    |  | 13.6                             |  | Permitted Transfers                        |  | 29  
|    |  | 13.7                             |  | No Release                                 |  | 30  
|    |  | 13.9                             |  | Occupancy                                  |  | 30  
|    |  |                                 
|14. |  | PERSONAL PROPERTY                |  | 30                                        
|    |  | 14.1                             |  | Installation and Removal                   |  | 30  
|    |  | 14.2                             |  | Responsibility                             |  | 30  
|    |  | 14.3                             |  | Landlords Lien                            |  | 31  
|    |  |                                 
|15. |  | END OF TERM                      |  | 31                                        
|    |  | 15.1                             |  | Surrender                                  |  | 31  
|    |  | 15.2                             |  | Holding Over                               |  | 31  
|    |  |                                 
|16. |  | ESTOPPEL CERTIFICATES            |  | 32                                        
|    |  |                                 
|17. |  | TRANSFERS OF LANDLORDS INTEREST |  | 32                                        
|    |  | 17.1                             |  | Sale, Conveyance and Assignment            |  | 32  
|    |  | 17.2                             |  | Effect of Sale, Conveyance or Assignment   |  | 32  
|    |  | 17.3                             |  | Subordination and Nondisturbance           |  | 32  
|    |  |                                 
|18. |  | RULES AND REGULATIONS            |  | 33                                        
|    |  |                                 
|19. |  | PARKING                          |  | 33                                        
|    |  | 19.1                             |  | Tenants Parking Rights                    |  | 33  
|    |  | 19.2                             |  | Parking Rules and Restrictions             |  | 34  
|    |  |                                 
|20. |  | DEFAULT AND REMEDIES             |  | 34                                        
|    |  | 20.1                             |  | Tenants Default                           |  | 44  
|    |  | 20.2                             |  | Landlords Remedies                        |  | 35  
|    |  | 20.3                             |  | Inducement, Recapture and Effect of Breach |  | 37  
|    |  | 20.4                             |  | Landlords Right to Perform                |  | 37  
|    |  | 20.5                             |  | Interest                                   |  | 38  
|    |  | 20.6                             |  | Late Charges                               |  | 38  



ii



---

TABLE OF CONTENTS

(continued)



|    |  |                                          |  |                                                           |  |     
|--- |  | ---------------------------------------- |  | --------------------------------------------------------- |  | ----
|    |  |                                          |  |                                                           |  | Page
|    |  | 20.7                                     |  | Landlords Default and Tenants Remedies                  |  | 38  
|    |  | 20.8                                     |  | Non-waiver of Default                                     |  | 39  
|    |  |                                         
|21. |  | SIGNAGE                                  |  | 39                                                       
|    |  | 21.1                                     |  | Signage                                                   |  | 39  
|    |  | 21.2                                     |  | Directory Board                                           |  | 39  
|    |  |                                         
|22. |  | SECURITY DEPOSIT  INTENTIONALLY OMITTED |  | 40                                                       
|    |  |                                         
|23. |  | BROKERS                                  |  | 40                                                       
|    |  |                                         
|24. |  | LIMITATIONS ON LANDLORDS LIABILITY      |  | 40                                                       
|    |  |                                         
|25. |  | QUIET ENJOYMENT                          |  | 40                                                       
|    |  |                                         
|26. |  | TELECOMMUNICATIONS                       |  | 40                                                       
|    |  | 26.1                                     |  | Certain Definitions                                       |  | 40  
|    |  | 26.2                                     |  | New Provider Installations                                |  | 41  
|    |  | 26.3                                     |  | Installation and Use of Other Communications Technologies |  | 41  
|    |  | 26.4                                     |  | No Obligation to Reserve Space                            |  | 41  
|    |  | 26.5                                     |  | Plans                                                     |  | 41  
|    |  | 26.6                                     |  | Limitation of Responsibility                              |  | 41  
|    |  | 26.7                                     |  | Necessary Service Interruptions                           |  | 42  
|    |  | 26.8                                     |  | Interference                                              |  | 42  
|    |  | 26.9                                     |  | Removal of Telecom Equipment, Wiring and Other Facilities |  | 42  
|    |  | 26.10                                    |  | No Third Party Beneficiary                                |  | 42  
|    |  |                                         
|27. |  | MISCELLANEOUS                            |  | 42                                                       
|    |  | 27.1                                     |  | Binding Effect                                            |  | 42  
|    |  | 27.2                                     |  | Complete Agreement; Modification                          |  | 42  
|    |  | 27.3                                     |  | Notices                                                   |  | 42  
|    |  | 27.4                                     |  | Delivery for Examination                                  |  | 43  
|    |  | 27.5                                     |  | No Air Rights                                             |  | 43  
|    |  | 27.6                                     |  | Enforcement Expenses                                      |  | 43  
|    |  | 27.7                                     |  | Relocation of Tenant. Intentionally Omitted.              |  | 43  
|    |  | 27.8                                     |  | Project Name                                              |  | 43  
|    |  | 27.9                                     |  | Recording; Confidentiality                                |  | 43  
|    |  | 27.10                                    |  | Captions                                                  |  | 43  
|    |  | 27.11                                    |  | Invoices                                                  |  | 43  
|    |  | 27.12                                    |  | Severability                                              |  | 43  
|    |  | 27.13                                    |  | Jury Trial                                                |  | 43  
|    |  | 27.14                                    |  | Authority to Bind                                         |  | 44  
|    |  | 27.15                                    |  | Only Landlord/Tenant Relationship                         |  | 44  
|    |  | 27.16                                    |  | Covenants Independent                                     |  | 44  
|    |  | 27.17                                    |  | Governing Law                                             |  | 44  
|    |  | 27.18                                    |  | Joint and Several Liability                               |  | 44  
|    |  | 27.19                                    |  | Counterparts                                              |  | 44  
|    |  | 27.20                                    |  | Signing Authority                                         |  | 44  
|    |  |                                         
|28. |  | OPTION TO RENEW                          |  | 45                                                       
|    |  |                                         
|29. |  | RIGHT OF FIRST OFFER                     |  | 45                                                       
|    |  |                                         
|30. |  | SUPPLEMENTAL HVAC AND BACK-UP EQUIPMENT  |  | 47                                                       
|    |  |                                         
|31. |  | SATELLITE EQUIPMENT                      |  | 48                                                       
|    |  |                                         
|32. |  | ATM USAGE                                |  | 49                                                       



iii



---

LEASE AGREEMENT

WESTLAKE PARK PLACE

THOUSAND OAKS, CALIFORNIA

THIS LEASE AGREEMENT (Lease) is entered into as of the Effective Date, and by and between Landlord and Tenant, identified in
Section 1.1 below.

1. BASIC LEASE DEFINITIONS, EXHIBITS AND ADDITIONAL DEFINITIONS.



| | 1.1 | Basic Lease Definitions
| | --- | -----------------------

In this Lease, the
following defined terms have the meanings indicated:

(a) Effective Date means that date set forth under
Landlords signature at the end of this Lease.

(b) Landlord means Westlake Plaza Center
East, LLC, a Colorado limited liability company.

(c) Tenant means First California Bank, a
California corporation, or if Tenant assigns this Lease to First California Financial Group, Inc., a Delaware corporation (Tenants Parent) pursuant to Section 13.6 of this Lease and such assignment constitutes a
Permitted Transfer as described therein, Landlord and Tenant shall amend this Lease such that Tenant shall mean First California Financial Group, Inc., a Delaware corporation.

(d) Project means the multiple office building project known as of the Effective Date as 2915, 2931, 2945, 3011, 3027,
3043, 3059, and 3075 Townsgate Road, Thousand Oaks, California, and related parking areas, walkways, landscaping areas and other common areas, less any portions that may be conveyed separately from the Building by Landlord from time to time. A
site plan of the Project, which contains approximately 462,328 Rentable Square Feet (as defined in Section 1.1(g) below), is attached hereto as Exhibit A. Notwithstanding the foregoing, Landlord and Tenant
acknowledge that the Project will be completed in two separate phases (Phase 1 and Phase 2) and it is currently contemplated that upon completion of Phase I, the Project will contain approximately 238,945
Rentable Square Feet (defined below) and that upon completion of Phase II, the Project will contain the approximate Rentable Square Feet noted above (i.e., 462,328 Rentable Square Feet).

(e) Building means the office building known as 3027 Townsgate Road, Thousand Oaks, California, in which the Premises
are located. The building contains approximately 60,466 Rentable Square Feet (as defined in Section 1.1(g) below).

(f) Premises means those premises known as Suite 300
located on the third (3rd) floor of the Building and identified on Exhibit B, which contain approximately 21,901
Rentable Square Feet and approximately 19,909 usable square feet (USF). The actual layout and square footage of the Premises shall be subject to the Construction Documents as defined in
Exhibit D and architectural measurement of the Premises, according to Exhibit C. The Premises do not include any areas above the finished ceiling or below the finished floor covering installed in the
Premises or any other areas not shown on Exhibit B as being part of the Premises. Landlord reserves, for Landlords exclusive use, any of the following (other than those installed for Tenants exclusive use) that
may be located in the Premises: stairways and stairwells; fan, mechanical, electrical, telephone and similar rooms; and elevator, pipe and other vertical shafts, flues and ducts. Landlord and Tenant acknowledge and agree that the measurement of the
Rentable Square Feet and USF of the Premises have been measured in accordance with the method set forth in Exhibit C. Upon completion of the Building, Tenant shall have the right to re-measure the Premises for purposes of
verifying the Rentable Square Feet and USF in the Premises, provided that any re-measurement of the Premises shall be (i) coordinated with Landlord so that Landlord may, at Landlords election, have a representative present during such
re-measurement, (ii) subject to all reasonable rules and regulations as may be promulgated by Landlord with regard to such entry onto the Premises, including, without limitation, the requirement that Tenant and Tenants architect or space
planner maintain (and provide evidence of) adequate liability insurance as reasonably determined by Landlord and (iii) made in strict accordance with the measurement



1



---

requirements and methodology set forth in Exhibit C (the Building Calculation Method). Tenant shall notify
Landlord of its desire to re-measure the Premises within five (5) days after receipt of notice from Landlord that the Building has been completed and shall complete such re-measurement within five (5) days thereafter. If Tenant fails to
notify Landlord of its desire to re-measure the Premises within the above 5-day period or otherwise fails to complete its re-measurement within the time period required above, Tenant shall have no further right to re-measure the Premises and the
Rentable Square Feet and USF of the Premises as set forth in this Lease shall be conclusive and binding upon Tenant. If based on a timely re-measurement by Tenant using the Building Calculation Method, the Rentable Square Feet of the Premises, the
USF of the Premises, or both, are different that as set forth in this Lease, then Landlord and Tenant shall enter into an amendment adjusting (either upward or downward) the actual Rentable Square Feet, USF, Base Rent, Tenants Proportionate
Share, the Tenant Improvement Allowance and such other items in this Lease calculated based on the amount of Rentable Square Feet or USF in the Premises. Notwithstanding the foregoing, in no event shall the USF be less than ninety percent (90%)
of the Rentable Square Feet of the Premises.

(g) Rentable Square Feet or RSF is
calculated pursuant to Exhibit C.

(h) Term means the duration of this Lease,
which will be approximately one hundred twenty-six (126) months and seven (7) days, beginning on the Commencement Date (as defined in Exhibit D) and ending on the Expiration Date (as
defined in the following sentence), unless terminated earlier or extended further as provided in this Lease. The Expiration Date means (i) if the Commencement Date is the first day of a month, the date which is one hundred
twenty-six (126) calendar months and seven (7) days from the date preceding the Commencement Date; or (ii) if the Commencement Date is not the first day of a month, the date which is one hundred twenty-six (126) calendar months
and seven (7) days from the last day of the month in which the Commencement Date occurs. If the Commencement Date is not the first day of the month, then for purposes of the schedule set forth in Section 1.1(j), Month 1
of the Term will be the first full calendar month after the Commencement Date, and Base Rent for the period beginning on the Commencement Date and ending on the day before the first day of Month 1 will be payable within five (5) days after the
Commencement Date at the same rate as set forth in Section 1.1(j) for Month 1, prorated based on the number of days in such period and the number of days in the month in which the Commencement Date occurs. Within fifteen (15) days after
Landlords written request, Tenant shall execute a written confirmation of the Commencement Date and Expiration Date of the Term in the form of the Notice of Lease Term Dates attached hereto as Exhibit E. The Notice of
Lease Term Dates shall be binding upon Tenant unless Tenant objects thereto in writing within such fifteen (15)-day period.

(i) Options to Extend means two (2) additional terms of five (5) years each.

(j)
Base Rent means the Rent payable according to Section 3.1, which will be in an amount per month or portion thereof during the Term equal to the product of (1) the Rentable Square Feet of the Premises and (2) the
Base Rent Per Rentable Square Foot for the respective month as follows:



|                                   |  |                                   |     
|---------------------------------- |  | --------------------------------- | ----
|Months                             |  | Base Rent Per RentableSquare Foot
|1                                  |  | $                                 | 2.81
|2  7 plus twenty-three (23) days* |  |                                   | 0   
|8 less twenty-three (23) days  24 |  | $                                 | 2.81
|25  48                            |  | $                                 | 2.97
|49  72                            |  | $                                 | 3.15
|73  96                            |  | $                                 | 3.34
|97  120                           |  | $                                 | 3.54
|121  126 plus seven (7) days      |  | $                                 | 3.75



|* | Tenants Base Rent abatement is subject to the terms and conditions set forth in Section 20.3.
|- | ----------------------------------------------------------------------------------------------



2



---

(k) Tenants Proportionate Share means two (2) separate
percentages which shall be adjusted (a) based on the RSF as determined by the final plans for the Building prepared by Landlords architect and (b) to the extent applicable, in connection with Tenants right to re-measure as set
forth in Section 1.1(f) above:

(i) Tenants Proportionate Share of the Building, which amount
is equal to a fraction, the numerator of which is the Rentable Square Feet of the Premises, and the denominator of which is the Rentable Square Feet of the Building, shall be 36.22%, subject to adjustment (a) based on the RSF as determined by
the final plans for the Building prepared by Landlords architect and (b) to the extent applicable, in connection with Tenants right to re-measure as set forth in Section 1.1(f) above, and

(ii) Tenants Proportionate Share of the Project, which amount is equal to a fraction, the numerator of which is
the Rentable Square Feet of the Premises, and the denominator of which is the Rentable Square Feet of the Project. Accordingly, upon completion of Phase I, Tenants Proportionate Share of the Project shall be 9.17% and upon completion of
Phase II, Tenants Proportionate Share of the Project shall be 4.74%, subject to adjustment if the RSF or USF is adjusted as provided in Section 1.1(f) above. In the event either the Building and/or the Project are expanded after the
Commencement Date, Tenants Proportionate Share shall be appropriately reduced, and as to the calendar year in which such changes occur, Tenants Proportionate Share for such calendar year shall be determined on the basis of the number of
days during this particular year such Tenants Proportionate Share was in effect.

(l) Landlords
Contribution to Operating Expenses means Tenants Proportionate Share of Operating Expenses incurred by Landlord during the Base Year, which shall consist of two (2) separate components:

(i) with respect to the Building Operating Expenses, Tenants Proportionate Share of the Building (as set forth in
Section 1.1(k)(i) above), multiplied by the Building Operating Expenses incurred during the Base Year; and

(ii) with
respect to the Project Operating Expenses, Tenants Proportionate Share of the Project (as set forth in Section 1.1(k)(ii) above) multiplied by the Project Operating Expenses incurred the Base Year.

(m) Base Year means the calendar year ending December 31, 2009.

(n) Permitted Use means banking and financial services (including, without limitation, loan approvals and processing,
deposit accounts, and other banking office and services), and general office use only.

(o) Security
Deposit: None.

(p) Landlords Managers Address means:

Steadfast Business Development LLC

4343 Von Karman Avenue

Newport Beach, CA 92660

Attention: Asset Management Department

(q) Landlords General
Address means:

The Amstar Group

1050 17thStreet, Suite 1200

Denver, CO 80265

Attention: Director of Office Investments

(r) Landlords Payment Address means:

Westlake Plaza Center East, LLC

c/o Steadfast Business Development LLC



3



---

4343 Von Karman Avenue

Newport Beach, CA 92660

Attention: Property Manager

(s) Tenants Notice Address means, for notices given before the Commencement Date:

First California Bank

1100 Paseo Camarillo

Camarillo, California 93010

Attention: C. G. Kum, President and Chief Executive Officer/Office of the President

and for notices given after the
Commencement Date:

3027 Townsgate Road, Suite 300

Thousand Oaks, California 91361

Attention: C. G. Kum, President and Chief Executive Officer/Office of
the President

(t) Tenants Invoice Address means:

3027 Townsgate Road, Suite 300

Thousand Oaks, California 91361

Attention: Ron Santarosa, Executive Vice President and Chief Financial Officer

(u) Brokers means Daum Commercial Real Estate Services, representing Landlord, and CB Richard Ellis, Inc.,
representing Tenant.

(v) Interest Rate means the lesser of: (a) the rate announced from time to
time by Bank of America (or if the entity named herein ceases to exist or ceases to publish such rate, by the largest (as measured by deposits) chartered bank operating in the state in which the Building is located) as its prime rate or
reference rate plus three percent (3%); or (b) the maximum rate permitted by law.

(w)
Leasehold Improvements means the Tenant improvements installed or to be installed by Tenant for the Premises as described in the Work Letter Agreement attached hereto as Exhibit D.

(x) Parking means four (4) unreserved parking spaces per each 1,000 USF leased by Tenant, which spaces shall be in
a location within reasonable proximity to the Building. Tenants use of the unreserved parking spaces shall be free of charge during the initial Term only; thereafter, Landlord may, in Landlords sole, subjective discretion, charge Tenant
a monthly fee for the use of such unreserved parking spaces at the then market rate as reasonably determined by Landlord. In addition, if Landlord offers reserved parking spaces to other tenants in the Project who are leasing RSF that is equal to or
less than the RSF then being leased by Tenant, Landlord shall notify Tenant of any such available reserved parking spaces then being offered and Tenant shall have a one-time right to purchase the number of such additional reserved parking spaces
equal to the product of (i) Tenants Proportionate Share of the Project (if the reserved spaces are offered to the tenants of the Project) or Tenants Proportionate Share of the Building (if the reserved spaces are offered only to
tenants of the Building and (ii) the number of reserved spaces then being offered by Landlord. The rate and the terms and conditions under which Landlord shall offer the reserved spaces shall be determine by Landlord in its sole, subjective
discretion; provided, however, that such rates, terms and conditions shall not be less favorable to Tenant than the rates, terms and conditions Landlord uses for other tenants at the time of the offer. Notwithstanding the foregoing, Tenants
right to purchase additional reserved parking spaces shall not apply to any short-term parking spaces.

(y)
Guarantor(s): None.



4



---

| | 1.2 | Exhibits and Riders
| | --- | -------------------

The Exhibits and Riders
listed below are attached to and incorporated in this Lease. In the event of any inconsistency between such Exhibits or Riders and the terms and provisions of this Lease, the terms and provisions of the Exhibits and Riders will control. The Exhibits
to this Lease are:



|            |  |                               
|----------- |  | ------------------------------
|Exhibit A |  | Site Plan of Project          
|Exhibit B |  | Plan Delineating the Premises 
|Exhibit C |  | Square Footage Determination  
|Exhibit D |  | Work Letter                   
|Exhibit E |  | Notice of Lease Term Dates    
|Exhibit F |  | Occupancy Estoppel Certificate
|Exhibit G |  | Form SNDA                     
|Exhibit H |  | Rules and Regulations         
|Exhibit I |  | Telecommunications Rules      
|Exhibit J |  | Signage                       
|Exhibit K |  | Parking Rules and Regulations 
|Exhibit L |  | Janitorial Specifications     



| | 1.3 | Additional Definitions
| | --- | ----------------------

In addition to those
terms defined in Section 1.1 and other Sections of this Lease, the following defined terms when used in this Lease have the meanings indicated:

(a) Additional Rent means the Rent payable according to Section 3.2.

(b) Affiliates of a party means that partys parent, subsidiary and affiliated corporations and its and their managers, members, partners, venturers, directors, officers, shareholders, agents, servants and employees.

(c) Building Standard means the scope and quality of leasehold improvements, Building systems or
Building services, as the context may require, generally offered from time to time to all office tenants of the Building.

(d) Business Hours means the hours from 8:00 a.m. to 6:00 p.m. on Monday through Friday and from 9:00 a.m. to 1:00 p.m. on Saturday, excluding statutory or legal holidays.

(e) Laws means any and all present or future federal, state or local laws, statutes, ordinances, rules, regulations or
orders of any and all governmental or quasi-governmental authorities having jurisdiction.

(f) Operating
Expenses shall mean collectively, the Project Operating Expenses and the Building Operating Expenses. As used herein, Building Operating Expenses shall mean all costs and expenses
for janitorial services for the Building (except as provided below), all costs and expenses for utilities which are separately metered to the Building (except as provided below), and all other reasonable costs and expenses of operation and
maintenance of the Building as determined by generally accepted accounting principles consistently applied, which Landlord may, from time to time, separately allocate to the Building, excluding, however, the Project Operating Expenses. For purposes
of determining the Building Operating Expenses incurred during the Base Year the Building Operating Expenses shall be calculated assuming the Building is ninety-five percent (95%) occupied (or calculated based on the actual level of occupancy
for the calendar year in question if the Building is more than ninety-five percent (95%) occupied) and Landlord had been supplying services and utilities to ninety-five percent (95%) of the Rentable Square Footage of the Building (or
calculated based on the actual level of occupancy for the calendar year in question if the Building is more than ninety-five percent (95%) occupied), excluding, however, the Project Operating Expenses. As used herein, Project Operating
Expenses shall mean all reasonable costs and expenses of operation and maintenance of the Project, as determined by generally accepted accounting



5



---

principles consistently applied, excluding, however, the Building Operating Expenses for buildings in the Project. For purposes of determining the Project
Operating Expenses incurred during the Base Year, the Project Operating Expenses shall be calculated assuming that all buildings in the Project are ninety-five percent (95%) occupied (or calculated based on the actual level of occupancy for the
calendar year in question if the all of the buildings in the Project are more than ninety-five percent (95%) occupied) and Landlord had been supplying services and utilities to ninety-five percent (95%) of the Rentable Square Footage of
the Building (or calculated based on the actual level of occupancy for the calendar year in question if the Building is more than ninety-five percent (95%) occupied), excluding, however, the Building Operating Expenses for the other buildings
in the Project. Project Operating Expenses shall include the following costs by way of illustration but not limitation: (i) Real Property Taxes and Assessments (as defined in Section 1.3(h) below) and any taxes or assessments imposed in
lieu thereof; (ii) any and all assessments imposed with respect to the Project pursuant to any covenants, conditions and restrictions affecting the Project and/or the Reciprocal Easement Agreement; (iii) water and sewer charges and the
costs of electricity, heating, ventilating, air conditioning and other utilities (except as provided below); (iv) utilities, surcharges and any other costs, levies or assessments resulting from statutes or regulations promulgated by any
governmental authority in connection with the use or occupancy of the Project or the parking facilities serving the Project; (v) costs of insurance obtained by Landlord pursuant to Section 9.1 of this Lease, including any deductibles
actually paid by Landlord so long as such deductible is consistent with deductibles under comparable insurance policies held by comparable landlords at comparable class projects (however in connection with earthquake or flood insurance, in the event
a deductible is actually incurred, the cost so incurred shall be amortized over the useful life of the items repaired); (vi) waste disposal and janitorial services (except as provided below); (vii) security; (viii) labor;
(ix) costs incurred in the management of the Project, including, without limitation: (1) supplies, (2) wages and salaries (and payroll taxes and similar governmental charges related thereto) of employees used directly in the
management, operation and maintenance of the Project (except as provided below), (3) Project management office rental (if such management office is located on the Project) at a cost not to exceed the fair market rental value for such office in
comparable suburban Class A office buildings in the Territory (as defined in Section 5.1 below), and excluding any portion of such office which is occupied principally for marketing purposes, and (4) a management /administrative fee
not to exceed five percent (5%) of the annual gross revenues of the Project exclusive of the proceeds of financing or a sale of the Project; (x) supplies, materials, equipment and tools; (xi) repair and maintenance of the elevators
and the structural portions of the improvements in the Project, including the plumbing, heating, ventilating, air-conditioning and electrical systems installed or furnished by Landlord (except as provided below); (xii) maintenance, costs and
upkeep of all parking and Common Areas (except as provided below); (xiii) depreciation on a straight line basis and rental of personal property used in maintenance; (xiv) amortization on a straight-line basis over the useful life of all
costs of a capital nature (including, without limitation, capital improvements, capital replacements, capital repairs, capital equipment and capital tools, provided that such capital expenditures satisfy either of the following two requirements of
this clause (xiv)): (1) such capital expenditures are reasonably intended to produce a material reduction in operating charges or energy consumption; or (2) such capital improvements are required after the Commencement Date of this
Lease under any Law that was not applicable to the Project as of the Commencement Date; (xv) costs and expenses of gardening and landscaping; (xvi) maintenance of signs (other than signs of tenants); (xvii) personal property taxes
levied on or attributable to personal property used in connection with the Project; (xviii) reasonable accounting, audit, verification, legal and other consulting fees (except as provided below); and (xix) costs and expenses of repairs,
resurfacing, repairing, maintenance, painting, lighting, cleaning, refuse removal, security and similar items, including appropriate reserves.

Notwithstanding the foregoing paragraph, Operating Expenses will not include (1) mortgage principal or interest; (2) ground lease payments; (3) leasing commissions; (4) costs of advertising space for lease in the
Project; (5) costs for which Landlord is reimbursed by insurance proceeds or from tenants of the Project (other than such tenants regular contributions to Operating Expenses); (6) any depreciation or capital expenditures (except as
expressly provided above); (7) costs directly and solely related to the maintenance



6



---

and operation of the entity that constitutes Landlord, such as accounting fees incurred for the purpose of reporting Landlords financial condition,
(8) any obligation for capital repairs or improvements, except to the extent such items reduce Operating expenses; (9) insurance deductibles; (10) costs associated with testing and remediation of Hazardous Materials (defined
below) or contaminants including asbestos and mold or mildew, unless caused by Tenant; (11) professional fees and expenses including attorneys and accountants for disputes with tenants, lease negotiation or preparation, completion of
partnership tax returns, and project financing matters; (12) costs and expenses for janitorial services provided to space within the Building that is leased on an exclusive basis to a tenant of the Building including, without limitation, the
janitorial costs paid by Tenant for the Premises, (13) electricity and other utilities consumed within any space within the Building that is leased on an exclusive basis to any tenant of the Building including, without limitation, separately
metered electricity and other utility costs paid by Tenant for the Premises, (14) fines, penalties, and interest except to the extent incurred due to an act or omission of Tenant, (15) wages, salaries and other compensation paid to any
executive employee of Landlord or Landlords Managing Agent above the grade of building manager or other similar level position, (16) any costs, fees, dues, contributions or similar expenses for political, charitable, industry association
or member organization, (17) acquisition costs for sculptures, paintings or other objects of art, (19) cost of alterations or improvements to the Premises or any other demised premises of other tenants in the Project or Building,
(20) overhead and profit increments paid to Landlord or to an Affiliate of Landlord for goods and/or services in the Building or Project to the extent the same exceeds the costs of such goods and/or services rendered by unaffiliated third
parties on a competitive basis for comparable buildings, (21) any Building or Project system, maintenance contract, or any type of insurance, unless such maintenance cost and/or insurance coverage was carried during the Base Year or, in the
alternative, such maintenance cost and/or insurance coverage, had it been carried during the Base Year, is added to determination of the Project Operating Expenses or the Building Operating Expenses, as applicable, incurred during the Base Year, and
(22) wages and fees in connection with the ownership, management, and operation of any parking structure to the extent of gross receipts from such parking operations. If services or insurance coverages are added or increased subsequent to the
Base Year that were not provided, or were not provided in the same quantities during the Base Year, then the costs of same shall, to the extent the cost would have been incurred in the Base Year, also be imputed into the Project Operating Expenses
or Building Operating Expenses, as applicable, incurred during the Base Year.

(g) Rent means the Base
Rent, Additional Rent and all other amounts required to be paid by Tenant under this Lease.

(h) Real Property
Taxes and Assessments mean any form of assessment, license fee, license tax, business license fee, commercial rental tax, levy, charge, improvement bond, tax or similar imposition imposed by any authority having the direct power to tax,
including any city, county, state or federal government, or any school, agricultural, lighting, drainage or other improvement or special assessment district thereof, as against any legal or equitable interest of Landlord in the Project, including
the following by way of illustration but not limitation:

(i) any tax on Landlords right to rent or
right to other income from the Premises or as against Landlords business of leasing the Premises;

(ii)
any assessment, tax, fee, levy or charge in substitution, partially or totally, of any assessment, tax, fee, levy or charge previously included within the definition of real property tax, it being acknowledged by Tenant and Landlord that Proposition
13 was adopted by the voters of the state of California in June 1978 election and that assessments, taxes, fees, levies and charges may be imposed by governmental agencies for such services as fire protection, street, sidewalk and road maintenance,
refuse removal and for other governmental services formerly provided without charge to property owners or occupants. It is the intention of Tenant and Landlord that, except as set forth below, all such new and increased assessments, taxes, fees,
levies and charges be included within the definition of real property taxes for the purpose of this Lease;



7



---

(iii) any assessment, tax, fee, levy or charge allocable to or measured by the area of
the Premises or other premises in the Project or the rent payable by Tenant hereunder or other tenants of the Project, including, without limitation, any gross receipts tax or excise tax levied by state, city or federal government, or any political
subdivision thereof, with respect to the receipt of such rent, or upon or with respect to the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises, or any portion thereof but not on
Landlords other operations;

(iv) any assessment, tax, fee, levy or charge upon this transaction or any document to
which Tenant is a party, creating or transferring an interest or an estate in the Premises; and/or

(v) any assessment, tax,
fee, levy or charge by any governmental agency related to any transportation plan, fund or system (including assessment districts) instituted for within the geographic area of which the Project is a part, but not imposed as a result of construction
of a new office building on the Project or expansion of the exterior of the Building.

Real Property Taxes and Assessments shall not include Landlords
federal or state income, franchise, inheritance or estate taxes, but for purposes of determining the Project Operating Expenses incurred during the Base Year, Real Property Taxes and Assessments shall include and be calculated assuming that the
Building and Project has been fully assessed for real property tax purposes as a completed building and project and is fully occupied with all tenant improvements in the Building and Project. Notwithstanding the foregoing, this paragraph shall not
be interpreted to exclude from the definition of Real Property Taxes and Assessment any assessments or supplemental taxes levied as a result of a transfer of the Project or any portion thereof.

2. GRANT OF LEASE.

2.1    Demise. Subject to the terms, covenants, conditions and provisions of this Lease, Landlord leases to Tenant and Tenant leases from Landlord the Premises, together with the nonexclusive right to use the
Common Areas, for the Term. Tenant and its employees and agents will have access to the Premises 24 hours per day, every day of the Term, subject to Landlords reasonable security measures.

2.2    Common Areas. During the Term of this Lease, Tenant shall have the nonexclusive right
to use, in common with Landlord, other tenants in the Project and landlord and tenants of the adjacent parcels under that certain Declaration of Covenants, Conditions, Restrictions and Reservation of Easements for Lot 1 of Tract No. 5245
recorded on April 28, 2003 in the Official Records of Ventura County, California as Instrument No. 2003-0139017-00 (the CC&Rs/REA), and subject to the Project Rules and Regulations referred to in
Section 18 below, those portions of the Project (the Project Common Areas) not leased or designated for lease to tenants that are provided for use in common by (or by the sublessees, agents, employees, customers or licensees of)
Landlord, Tenant and any other tenants of the Project, whether or not those areas are open to the general public. The Project Common Areas shall include, without limitation, any fixtures, systems, decor, facilities and landscaping contained,
maintained or used in connection with those areas, and shall be deemed to include any sidewalks adjacent to the Project, any pedestrian walkway system, parking or other facilities open to the general public. The common areas appurtenant to the
Building shall be referred to herein as the Building Common Areas and shall include the following areas:

(a)
the common entrances, lobbies, restrooms on multi-tenant floors, elevators, stairways and access ways, loading docks, ramps, drives and platforms and any passageways and serviceways thereto, and the common pipes, conduits, wires and appurtenant
equipment serving the Premises; and

(b) the parking structure and parking areas (subject to Section 19 below), loading
and unloading areas, trash areas, roadways, sidewalks, walkways, parkways, driveways and landscaped areas and plaza area appurtenant to the Building.

The Building Common Areas and the Project Common Areas shall be referred to herein collectively as the Common Areas.



8



---

2.3    Landlords Reserved Rights.
Landlord reserves the right from time to time to use any of the Common Areas and to do any of the following, as long as such acts do not materially increase Tenants costs or unreasonably interfere with Tenants use of or access to the
Premises:

(a) expand the Building and construct or alter other buildings or improvements within the Project;

(b) make any changes, additions, improvements, repairs or replacements in or to the Project, the Common Areas and/or the Building
(including the Premises if required to do so by any law or regulation) and the fixtures and equipment thereof, including, without limitation: (i) maintenance, replacement and relocation of pipes, ducts, conduits, wires and meters, and
(ii) changes in the location, size, shape and number of driveways, entrances, stairways, elevators, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas and walkways, and subject to Section 19 parking spaces
and parking areas; in particular, Landlord shall have the right to construct an additional parking structure to serve the Project, it being understood that in connection therewith, Landlord may relocate Tenants then existing parking spaces to
either the new parking structure or elsewhere within the parking area serving the Building;

(c) close temporarily any of
the Common Areas while engaged in making repairs, improvements or alterations to the Project and/or Building so long as Tenant is provided with reasonable access to the Premises and reasonable parking; and

(d) perform such other acts and make such other changes with respect to the Project, Common Areas and Building as Landlord may, in the
exercise of sound business judgment, deem to be appropriate.

In effectuating any of the foregoing, Landlord shall use commercially
reasonable efforts to perform any work in a manner that will not unreasonably interfere with Tenants business operations.

3. RENT.

3.1    Base Rent.
Commencing on the Commencement Date and then throughout the Term, Tenant agrees to pay Landlord Base Rent according to the following provisions. Base Rent during each month (or portion of a month) described in Section 1.1(i) will be payable in
equal monthly installments for such month (or portion), in advance, on or before the first day of each and every month during the Term; provided, however, that payment of Base Rent for Month 1 of the Lease Term (as defined in Section 1.1(h))
shall be made upon execution of this Lease by Tenant. Furthermore, if the Lease Term terminates on a date other than last day of a calendar month, Base Rent for the calendar month in which Lease termination occurs will be adjusted on a prorated
basis, based on the ratio of the number of days of the Lease Term that fall within said calendar month as compared to the total number of days within said calendar month.

3.2    Additional Rent. All amounts and charges payable to Tenant under this Lease in addition to the Rent described in above (including, without limitation,
payments for insurance, repairs and Excess Expenses as provided in Section 3.3 below) shall be considered additional rent for the purposes of this Lease, and the word rent in this Lease shall include such additional rent unless the
context specifically or clearly implies that only the Base Rent is referenced. The Base Rent and additional rent shall be paid to Landlord as provided in Section 3.8, without any prior demand therefor and without any deduction or offset
whatsoever, in lawful money of the United States of America.

3.3    Excess
Expenses. Commencing with calendar year 2010, Tenant shall pay to Landlord, in the manner and at the times set forth in the following provisions of Sections 3.4 and 3.5, the amount by which Tenants Proportionate Share of Operating
Expenses (which consists of two (2) separate components as set forth in Section 1.1(k) above) exceeds Landlords Contribution to Operating Expenses (which consists of two (2) separate components as set forth in
Section 1.1(l) above). Such excess amounts shall be collectively referred to in this Lease as the Excess Expenses.

3.4    Estimate Statement. By the first day of April of each calendar year during the Term of this Lease commencing with calendar year 2010, Landlord shall use commercially
reasonable efforts to deliver to Tenant a statement (Estimate Statement ) estimating the Operating Expenses for the current calendar year and the



9



---

estimated amount of Excess Expenses payable by Tenant. Landlord shall have the right during any calendar year to deliver a revised Estimate Statement showing
the Excess Expenses for such calendar year if Landlord reasonably and actually determines that the Excess Expenses are greater than or less than those set forth in the original Estimate Statement (or previously delivered revised Estimate Statement)
for such calendar year. The Excess Expenses shown on the Estimate Statement (or revised Estimate Statement, as applicable) shall be divided into twelve (12) equal monthly installments, and Tenant shall pay to Landlord, concurrently with the
regular monthly Base Rent payment next due following the receipt of the Estimate Statement (or revised Estimate Statement, as applicable), an amount equal to one (1) monthly installment of such Excess Expenses multiplied by the number of months
from January in the calendar year in which such statement is submitted to the month of such payment, both months inclusive (less any amounts previously paid by Tenant with respect to any previously delivered Estimate Statement or revised Estimate
Statement for such calendar year); provided, however, that with respect to the first Estimate Statement submitted, Tenant shall also pay the Excess Expenses for those months of the calendar year 2010, if any, during the Term which occurred prior to
the date in which such first Estimate Statement is submitted. Subsequent Installments shall be paid concurrently with the regular monthly Base Rent payments for the balance of the calendar year and shall continue until the next calendar years
Estimate Statement (or current calendar years revised Estimate Statement) is received.

3.5    Actual Statement. By the first day of April of each succeeding calendar year during the Term of this Lease commencing with calendar year 2010, Landlord shall use
commercially reasonable efforts to deliver to Tenant a reasonably detailed statement (Actual Statement) of the actual Operating Expenses and Excess Expenses for the immediately preceding calendar year, it being understood that the
Actual Statement for the calendar year 2010 shall be for the Base Year Operating Expenses. If the Actual Statement reveals that Excess Expenses were overstated or understated in any Estimate Statement (or revised Estimate Statement) previously
delivered by Landlord pursuant to Section 3.4, then within thirty (30) days after delivery of the Actual Statement, Tenant shall pay to Landlord the amount of any such underpayment, or, Landlord shall pay to Tenant (or credit against the
next monthly Base Rent and Excess Expense installment falling due), the amount of such overpayment, as the case may be.

3.6    No Release. Any delay or failure by Landlord in delivering any Estimate or Actual Statement pursuant to Sections 3.4 and 3.5 above shall not constitute a waiver of its right to receive Tenants
payment of Excess Expenses, nor shall it relieve Tenant of its obligations to pay Excess Expenses pursuant to Section 3.4 above, except that Tenant shall not be obligated to make any payments based on such Estimate or Actual Statement until
thirty (30) days after receipt of such statement.

3.7    Other Taxes.
Tenant will reimburse Landlord upon demand for any and all taxes paid by Landlord (other than net income taxes and other taxes excluded from the definition of Real Property Taxes and Assessments) whether or not now customary or within the
contemplation of Landlord and Tenant: (a) upon, measured by or reasonably attributable to the cost or value of Tenants equipment, furniture, fixtures and other personal property located in the Premises; (b) upon or measured by Rent
(other than net income taxes and other taxes excluded from the definition of Real Property Taxes); (c) upon or with respect to the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of the
Premises or any portion of the Premises; and (d) upon this transaction or any document to which Tenant is a party creating or transferring an interest or an estate in the Premises.

3.8    Terms of Payment. All Base Rent, Additional Rent and other Rent will be paid, at
Landlords Payment Address or to such other person or at such other place as Landlord may from time to time designate in writing, without notice or demand and without right of deduction, abatement or set-off, except as otherwise expressly
provided in this Lease.

3.9    Right to Accept Payments. No receipt by
Landlord of an amount less than Tenants full amount due will be deemed to be other than payment on account, nor will any endorsement or statement on any check or any accompanying letter effect or evidence an accord and
satisfaction. Landlord may accept such check or



10



---

payment without prejudice to Landlords right to recover the balance or pursue any right of Landlord. No payments by Tenant to Landlord: (a) after
the expiration or other termination of the Term will reinstate, continue or extend the Term; or (b) will invalidate or make ineffective any notice (other than a demand for payment of money) given prior to such payment by Landlord to Tenant.
After notice or commencement of a suit, or after final judgment granting Landlord possession of the Premises, Landlord may receive and collect any sums of Rent due under this Lease, and such receipt will not void any notice or in any manner affect
any pending suit or any judgment obtained.

3.10     Audit Rights. If Tenant
disputes any amounts set forth in any Actual Statement, Tenant will have the right no later than one hundred twenty (120) days following receipt of that Actual Statement to cause Landlords books and records regarding the particular
amount(s) being disputed by Tenant to be reviewed, copied, and/or audited by Tenant, by Tenants internal accountant or by another certified public accounting firm or other auditing firm which has prior experience in the review of operating
expenses and which is not being compensated on a contingent fee basis; provided, however, that any such audit shall be subject to the following: (i) Tenant shall not have the right to perform any such audit more than one (1) time for any
calendar year during the Lease Term, (ii) Tenants audit shall be limited to a review of those Operating Expenses for the immediately preceding year, it being understood that Tenant shall have waived its right to audit Operating Expenses
for the year to which an Actual Statement relates unless Tenant delivers notice to Landlord of its intent to audit such Operating Expenses within ninety (90) days after receipt of an Actual Statement. Any audit conducted by or on behalf of
Tenant shall be conducted at Landlords office in the Project during Landlords normal business hours and in the manner so as to minimize interference with Landlords business operations. Tenants audit shall be limited to
an on-site audit, review and/or copying of Landlords books and records with respect to only the calendar year being audited by Tenant, the Project, the Building and the particular amount(s) being disputed by Tenant. Upon completion of
Tenants audit, Tenant shall provide Landlord with a copy of such audit and the results resulting from that audit. If Landlord agrees with the results of Tenants audit, the amounts payable under Sections 3.4 and 3.5 hereof by
Landlord to Tenant or by Tenant to Landlord, as the case may be, will be appropriately adjusted on the basis of such audit. If Landlord disagrees with the results of Tenants audit, Landlord shall have the right to cause another review to be
made by an independent auditor selected by Landlord and reasonably approved by Tenant, in which case, the results of Landlords audit shall be binding upon the parties. If Tenants audit (or Landlords audit if applicable) discloses
an overstatement of Operating Expenses in excess of five percent (5%) for such calendar year, Tenant will receive a credit against Tenants future Operating Expense obligations for the reasonable costs of Tenants audit not to exceed
the amount of the overcharge; otherwise the cost of such audit, including Landlords costs incurred in complying with such audit, shall be borne by Tenant.

4. USE AND OCCUPANCY.

4.1    Use. Tenant agrees to use and occupy the Premises only for the Use described in Section 1.1(g), or for such other purpose as Landlord expressly authorizes in writing,
and for no other purposes.

4.2    Compliance. Tenant agrees to use the
Premises in a safe, careful and proper manner, and to comply with all Laws applicable to Tenants use, occupancy or alteration of the Premises or the condition of the Premises resulting from such use, occupancy or alteration, at Tenants
sole cost and expense.

4.3    Occupancy. Tenant will not do or permit anything
which obstructs or interferes with other tenants rights or with Landlords providing Project services, or which injures or annoys other tenants. Tenant will not cause, maintain or permit any nuisance in or about the Premises and will keep
the Premises free of debris, and anything of a dangerous, noxious, toxic or offensive nature or which could create a fire hazard or undue vibration, heat or noise. If any item of equipment, building material or other property brought into the
Project by Tenant or on Tenants request causes a dangerous, noxious, toxic or offensive effect (including an environmental effect) and in Landlords reasonable opinion such effect will not be permanent but will only be temporary and is
able to be eliminated, then Tenant will not be required to remove such item, provided that Tenant promptly and diligently causes such effect to be eliminated, pays for all costs of elimination and indemnifies Landlord against all liabilities arising
from such



11



---

effect. Tenant will not make or permit any use of the Premises which may jeopardize any insurance coverage, increase the cost of insurance or require
additional insurance coverage. If by reason of Tenants failure to comply with the provisions of this Section 4.3, insurance premiums are increased, then Landlord may require Tenant to immediately pay Landlord as Rent the amount of the
increase in insurance premiums.

4.4    Hazardous Material.

(a) The term Hazardous Material as used in this Lease means any product, substance, chemical, material, or waste whose
presence, nature, quantity and/or intensity of existence, use, manufacture, disposal, transportation, spill, release, or effect, either by itself or in combination with other materials expected to be on or about the Premises is designated as such or
otherwise contemplated under any Environmental Law (as defined below). The term Hazardous Material will include, but not be limited to, hydrocarbons, petroleum, gasoline, crude oil, or any products, by-products or fractions thereof, asbestos,
chlorofluorocarbons, polychlorinated biphenyls (PCBs) and formaldehyde. The provisions of this Section 4.4(a) will extend to any and all such Hazardous Material whether or not such substance was defined, recognized, or known or suspected
of being hazardous, toxic, dangerous, or wasteful, at the time of any act or omission giving rise to Tenants liability. The term Environmental Laws shall mean the Comprehensive Environmental Response, Compensation and
Liability Act of 1980 (42 U.S.C. §§ 9601 et seq.), any so-called Superfund or Superlien law, the Resource Conservation and Recovery Act of 1980 (42 U.S.C. §§ 6901 et seq.),
the Federal Water Pollution Control Act (33 U.S.C. §§ 1251 et seq.), the Safe Drinking Water Act (42 U.S.C. §§ 300f et seq.), the Toxic Substances Control Act (15 U.S.C. §§ 2601
et seq.), the Clean Air Act (42 U.S.C. §§ 7401 et seq.), California Health & Safety Code §§ 25100 et seq. and §§ 39000 et seq., the California Safe Drinking
Water & Toxic Enforcement Act of 1986 (California Health & Safety Code §§ 25249.5 et seq.), the Porter-Cologne Water Quality Control Act (California Water Code §§ 13000 et seq.), any and all
amendments and recodifications of the foregoing statutes, or any other federal, state, local, or other statute, law, ordinance, code, rule, regulation, permit, order, or decree regulating, relating to or imposing liability or standards of conduct
concerning Hazardous Material.

(b) In addition to its other obligations under this Lease (including Section 4.2
hereof), Tenant covenants to comply with all Environmental laws with respect to the Premises, the Building and the Project to the extent relating to actions or operations by Tenant, its agents, officers, contractors, employees, assignees, subtenants
and/or invitees (collectively, the Tenant Parties or each, a Tenant Party). Except for general office supplies typically used in an office area in the ordinary course of business (such as copier toner, liquid
paper, glue, ink, and cleaning solvents), except for petroleum, oils, and other items used in connection with the operation of automobiles and other equipment, and except for common and customary construction materials (including, without
limitation, solvents, lubricants, fuels, mastics and adhesives) and common cleaning and janitorial supplies reasonably necessary for the maintenance, operation, repair and improvement of the Premises, for use in the manner for which they were
designed and only in accordance with all Hazardous Materials laws and reasonable prudent standards prevailing in the industry for such use, and then only in such amounts as may be normal for the office business operations conducted by Tenant on the
Premises, neither Tenant nor any Tenant Parties shall use, handle, store or dispose of any Hazardous Materials in, on, under or about the Premises, the Building or the Project. Tenant shall promptly take all actions, at its sole cost and expense, as
are necessary to return the Premises, Building, and Project to the condition existing prior to the introduction of any such Hazardous Materials by Tenant or any Tenant Parties, provided Landlords approval of such actions shall first be
obtained, except in the case of an emergency, in which case Tenant shall notify Landlord of such actions as soon as is reasonably possible. In addition, neither Tenant nor any Tenant Parties shall cause or permit the Premises to be used to generate
any noxious substances or, except as expressly permitted by this Section 4.4, Hazardous Materials, to be released into, flow or seep into, or be placed into the Premises. Tenant shall promptly take all actions, at its sole cost and expense, as
are necessary to maintain the Premises, Building, and Project in the condition existing prior to the introduction of any Hazardous Materials and/or noxious substances by Tenant or any Tenant Parties. Tenant shall promptly provide Landlord with any
notices relating to Hazardous Materials which Tenant is obligated to provide Landlord under Environmental Laws.



12



---

(c) In addition to any other indemnity contained in this Lease, Tenant shall be solely
responsible for and shall indemnify, defend (with counsel reasonably approved by Landlord) and hold Landlord, its partners, managers, members, officers, directors, subsidiaries, affiliates, lenders, employees and agents, and the property manager of
the Project (Property Manager) and ground lessor, if any, and the Premises, harmless from and against any and all claims, judgments, suits, causes of action, damages, penalties, fines, liabilities, losses and expenses (including,
without limitation, investigation and clean-up costs, attorneys fees, consultant fees and court costs) which arise during or after the Term of this Lease as a result of Tenants breach of any of the obligations and covenants set forth in
Section 4.4(b) above and/or any contamination of the Premises, Building or Project directly or indirectly arising from the activities of Tenant or any Tenant Parties. Notwithstanding the foregoing, the foregoing indemnity shall not apply to,
and Tenant shall not be responsible for, any claims, costs or expenses relating to the remediation or cleanup of Hazardous Materials which were located on, under or about the Project prior to the date of this Lease or which are placed or discharged
on or about the Project by either Landlord and/or its employees, contractors, agents or persons, or any other persons or entities other than Tenant or any Tenant Party.

(d) Tenant will promptly comply with the requirements of Section 25359.7(b) of the California Health and Safety Code and/or any
successor or similar statute. Accordingly, if Tenant knows, or has reasonable cause to believe, that Hazardous Material, or a condition involving or resulting from same, has come to be located in, on, under, or about the Premises, other than as
previously consented to by Landlord, Tenant will promptly give written notice of such fact to Landlord. Tenant will also promptly give Landlord a copy of any statement, report, notice, registration, application, permit, business plan, license,
claim, action, or proceeding given to, or received from, any governmental authority or private party, or persons entering or occupying the Premises, concerning the presence, spill, release, discharge off, or exposure to, any Hazardous Material, in,
on, under, or about the Premises. Should Tenant fail to so notify Landlord, Landlord will have all rights and remedies provided for such a failure by such Section 25359.7(b) in addition to all other rights and remedies which Landlord may have
under this Lease or otherwise. Additionally, Tenant will immediately notify Landlord in writing of (i) any enforcement, clean-up, removal, or other governmental action instituted, completed, or threatened with regard to Hazardous Material
involving the Premises, the Building, or the Project of which Tenant has received written notice or of which Tenant otherwise has actual knowledge, (ii) any claim made or threatened by any person against Tenant, Landlord, the Premises, the
Building, or the Project related to damage, contribution, cost recovery, compensation, loss, or injury resulting from or claimed to result from any Hazardous Material of which Tenant has received written notice or of which Tenant otherwise has
actual knowledge, (iii) any reports made to any environmental agency arising out of or in connection with any Hazardous Material at or removed from the Premises, the Building, or the Project, including any complaints, notices, warnings, or
assertions of any violation in connection therewith of which Tenant has received written notice, or (iv) any spill, release, discharge, or disposal of Hazardous Material that occurs with respect to the Premises or Tenants operations,
including, without limitation, those that would constitute a violation of California Health and Safety Code Section 25249.5 or any other Applicable Environmental Law (defined below).

(e) Tenant will promptly abate any Hazardous Material brought, placed or leaked onto, or under the Premises during the Term of the Lease
by Tenant or any Tenant Party. Additionally, to the extent Tenant or any Tenant Party brings, places, holds, treats, disposes of, or utilizes any chlorofluorocarbons on or about the Premises, Tenant will remove all such chlorofluorocarbons prior to,
or upon, termination of the Lease, regardless of whether such chlorofluorocarbons are then defined, recognized, known or supposed to be Hazardous Material. Tenant, however, will not take any remedial action related to Hazardous Material located in
or about the Premises, the Building, or the Project and will not enter into a settlement, consent decree, or compromise in response to any claim related to Hazardous Material, without first notifying Landlord in writing of Tenants proposed
action and affording Landlord a reasonable opportunity to appear, intervene, or otherwise participate in any discussion or proceeding for the purposes of protecting Landlords interest in the Premises, the Building, and the Project.



13



---

(f) Landlord and Landlords lender(s) will have the right to enter the Premises at
any time in the case of an emergency, and otherwise at reasonable times upon reasonable prior notice to Tenant, for the purpose of inspecting the condition of the Premises and for verifying compliance by Tenant with the terms of this
Section 4.4 and all Environmental Laws, and to employ experts and/or consultants in connection therewith and/or to advise Landlord with respect to Tenants activities including but not limited to the installation, operation, use,
monitoring, maintenance, or removal of any Hazardous Material from the Premises. The costs and expenses of such inspection will be paid by the party requesting same, unless a Default of this Lease, or violation of Environmental Law, or a
contamination caused or contributed by Tenant or any Tenant Party is found to exist, or unless the inspection is required or ordered by governmental authority as the result of any such existing violation or contamination. In any such case, Tenant
will upon request reimburse Landlord or Landlords lender(s), as the case may be, for the reasonable costs and expenses of such inspections to the extent caused or otherwise contributed by Tenant or any Tenant Party.

(g) The foregoing covenants and indemnities of Tenant shall survive the expiration or earlier termination of this Lease.

(h) In the event that any Hazardous Material is brought, placed, or leaked onto, under or about the Premises, Building and/or Project by a
person other than Tenant or a Tenant Party and as a result thereto, Tenant is prevented from using, and does not use, the Premises or any portion thereof for seven (7) consecutive business days after receipt by Landlord of Tenants written
notice that Tenant is so prevented from using all or a portion of the Premises (or fifteen (15) business days in any consecutive twelve (12)-month period provided Landlord received Tenants written notice covering all such
business days that Tenant was so prevented from using and does not use the Premises or any portion thereof) (the Eligibility Period), then the Rent shall be abated during the period beginning on the date Tenant actually does not
use the Premises or any portion thereof as a result of the Hazardous Material condition and throughout such period that Tenant continues to be so prevented from using and does not use the Premises or portion thereof, in the proportion that the
Rentable Square Feet of the portion of the Premises that Tenant is prevented from using, and does not use, the Premises bears to the total Rentable Square Feet of the Premises. However, in the event that Tenant is actually prevented from using, and
does not use any portion of the Premises and the remaining portion of the Premises is not sufficient to allow Tenant to effectively conduct its business thereon, and if Tenant does not conduct its business from such remaining portion of the
Premises, then for such time that Tenant is so prevented from effectively conducting its business in the Premises, the Rent for the entire Premises shall be abated; provided, however, that if Tenant reoccupies and uses any portion of the Premises
during such period, the Rent allocable to such reoccupied portion, based on the proportion that the Rental Square Feet of such reoccupied portion of the Premises bears to the total Rental Square Feet of the Premises, shall be payable by Tenant from
the date Tenant reoccupies such space. If Tenants right to abatement occurs during a free rent period which arises after the Commencement Date, Tenants free rent period shall be extended for the number of days that the abatement period
overlapped the free rent period (Overlap Period). Notwithstanding the foregoing, Tenant shall not be deemed to be using the Premises for purposes of this Section 4.4(h) if Tenant is merely maintaining a skeleton crew within
the affected Premises for such purposes as securing Tenants records and files, forwarding telephone communications, correspondence and deliveries, and/or otherwise enabling those aspects of Tenants business operations previously
conducted within the affected Premises to be carried on from an alternative location.

5. SERVICES AND UTILITIES.

5.1    Landlords Standard Services. Subject to the terms and conditions
of this Lease, and the obligations of Tenant as set forth herein below, Landlord shall furnish or cause to be furnished to the Premises the following utilities and services in a manner consistent with other comparable Class A quality office
buildings located in the Thousand Oaks/Westlake Village/Agoura Hills/Calabasas, California area (the Territory), the costs of which shall be included in Operating Expenses, unless otherwise specified below (Landlord reserves the right to
adopt non-discriminatory modifications and additions to the following provisions from time to time so long as such



14



---

modifications do not materially decrease the level of service provided to Tenant, materially reduce Tenants rights, or materially increase
Tenants monetary obligations):

(a) Landlord shall make available for Tenants nonexclusive use, the non-attended
passenger elevator facilities of the Building, seven days per week and twenty-four (24) hours per day. Subject to the other terms and provisions of this Lease and reasonable Building access restrictions from equipment and other measures
that may be established by Landlord (for example, card key access), Tenant shall have access to the Premises seven (7) days per week, twenty-four (24) hours per day. Subject to the terms and conditions of this Lease, Tenant shall
(i) cause the Premises to be separately metered for all utilities, at its sole cost and expenses as part of the Leasehold Improvements as defined in Exhibit Dand subject to the application of the Tenant Improvement
Allowance, and (ii) pay directly all costs of electricity consumed within or for the exclusive benefit of the Premises, including but not limited to electricity for lighting, power and the heating, ventilation and air conditioning
(HVAC) system serving the Premises. Accordingly, Tenant shall contract directly with all utility providers and shall pay for all gas, heat, light, power, telephone and trash disposal supplied to the Premises, together with any taxes,
charges and fees thereon. Tenant shall be responsible for all utility charges from and after the Commencement Date and, if such utility charges are charged to Landlord, Landlord may elect to deduct such amounts from the Tenant Improvement Allowance
(as defined in the Work Letter Agreement). In the event it is not possible for Tenant to separately obtain a usual and customary utility service, the utility service shall be obtained in Landlords name, and Tenant will pay directly to Landlord
as Additional Rent, the Actual Costs incurred by Landlord in providing such utility services and such costs shall be excluded from Operating Expenses to the extent paid for directly by Tenant. As used herein, Actual Costs for
utilities shall mean the rate charged for the provision of the utility by the local public utility furnishing the utility. Landlord reserves the right to separately meter any such electricity service at Tenants expense at any time during the
Lease Term.

(b) The cost of maintenance and service calls to adjust and regulate the HVAC system shall be charged to Tenant
if the need for maintenance work results from either Tenants unreasonable adjustment of room thermostats or Tenants failure to comply with its obligations under this Section 5. Such work shall be charged at hourly rates not higher
than that which is charged for comparable work for Landlords own account.

(c) Unless otherwise consented to by
Landlord in Landlords sole, subjective discretion, in no event shall Tenants use of electric current ever exceed the capacity of the feeders to the Building or the risers or wiring installation of the Building. Landlord shall also
furnish hot and cold water to the Premises twenty-four (24) hours per day, seven (7) days per week for drinking, kitchen, and lavatory purposes, in such quantities as are typical for comparable Class A quality office buildings
located in the Territory. If Tenant requires or consumes water in excess of what is set forth in the foregoing sentence, Landlord may require Tenant to pay to Landlord, as additional rent, the Actual Costs incurred for such excess usage, together
with an administrative fee equal to five percent (5%) of such Actual Costs to cover Landlords overhead.

(d)
Tenant shall furnish janitorial services at its sole cost and expense to the Premises five (5) days per week and Landlord shall furnish janitorial services to the remainder of the Project at its sole cost and expense which may be included in
Operating Expenses pursuant to janitorial and cleaning specifications as set forth on Exhibit Lor pursuant to other standards that Landlord may adopt from time to time which shall be consistent with the standards typical for
comparable Class A quality office buildings located in the Territory and which shall not be materially less than the specifications set forth in Exhibit L. No person(s) other than those persons approved by Landlord shall
be permitted to enter the Premises for such purposes. Janitor service by Tenant shall include without limitation ordinary dusting, vacuuming and cleaning by the janitor assigned to do such work. Window cleaning shall be done only by Landlord, at
such time and frequency as reasonably determined by Landlord but not less than as required by Exhibit L attached hereto. Tenant shall pay to Landlord the cost of removal of any of Tenants refuse and rubbish to the
extent that the same exceeds the refuse and rubbish usually attendant upon the Permitted Use of the Premises.



15



---

(e) At Landlords option (to the extent not already done by Tenant), and subject to
the provisions of Section 5.1(c) above, Landlord may install water, electricity and/or HVAC meters in the Premises to measure Tenants consumption of such utilities, including any after-hours and extraordinary usage described above.

5.2    Tenants Obligations. Tenant shall cooperate fully at all times
with Landlord, and abide by all reasonable and non-discriminatory regulations and requirements which Landlord may prescribe for the proper functioning and protection of the Buildings services and systems; provided such regulations will not
unreasonably interfere with Tenants business operations. Tenant shall not use any apparatus or device in, upon or about the Premises which may in any way increase the amount of services or utilities usually furnished or supplied to the
Premises or other premises in the Building. In addition, Tenant shall not connect any conduit, pipe, apparatus or other device to the Buildings water, waste or other supply lines or systems for any purpose without first obtaining
Landlords written consent. Neither Tenant nor its employees, agents, contractors, licensees or invitees shall at any time enter, adjust, tamper with, touch or otherwise in any manner affect the Building Structure or Building Systems (as
defined in Section 6.3).

5.3    Interruption of Services. If any of the
services provided for in this Section 5 are interrupted or stopped, Landlord will use due diligence to resume the service; provided, however, no irregularity or stoppage of any of these services will create any liability for Landlord
(including, without limitation, any liability for damages to Tenants personal property caused by any such irregularity or stoppage), constitute an actual or constructive eviction or, cause any abatement of the Rent payable under this Lease or
in any manner or for any purpose relieve Tenant from any of its obligations under this Lease; provided, however, that if any of the services are interrupted or stopped for a period of longer than the Eligibility Period and the interruption is a
direct result of Landlords failure to perform an express obligation of Landlord under this Lease that was otherwise within Landlords reasonable control, or if any of the services are interrupted or stopped for a period of
fourteen (14) consecutive business days for any reason outside of the reasonable control of Landlord (or thirty (30) business days in any consecutive twelve (12)-month period) and should Tenant be actually prevented from using the
Premises, then the Rent shall be abated during the period beginning on the date Tenant actually cannot and does not use the Premises or any portion thereof as a result of the interruption in services and throughout such period that Tenant continues
to be so prevented from using the Premises and does not, in the proportion that the Rentable Square Feet of the portion of the Premises that Tenant is prevented from using, and does not use, the Premises bears to the total Rentable Square Feet of
the Premises. Notwithstanding the foregoing, if Tenant reoccupies and uses any portion of the Premises during such period, the Rent allocable to such reoccupied portion, based on the proportion that the Rental Square Feet of such reoccupied portion
of the Premises bears to the total Rental Square Feet of the Premises, shall be payable by Tenant from the date Tenant reoccupies such space. Without limiting those reasons for an irregularity or stoppage of services that may be beyond
Landlords control, any such irregularity or stoppage that is required in order to comply with any Laws or that is required or recommended by governmental agencies for health or safety reasons will be deemed caused by a reason beyond
Landlords control. Tenant hereby waives the provisions of Sections 1932, 1933(4) and 1942 of the Civil Code of California or any similar or successor statutes to the fullest extent permitted by Laws, and Tenant acknowledges that, in the
event Landlord fails to make a repair or perform maintenance, Tenants sole remedy for such breach by Landlord, in addition to the abatement of Rent provided for in this Section, will be an action for damages, and that Tenant will not be
entitled to terminate this Lease, withhold Rent, or make any repair and deduct the cost of repair from Rent payable under this Lease. Notwithstanding the foregoing, Tenant shall not be deemed to be using the Premises for purposes of this
Section 5.3 if Tenant is merely maintaining a skeleton crew within the affected Premises for such purposes as securing Tenants records and files, forwarding telephone communications, correspondence and deliveries, and/or otherwise
enabling those aspects of Tenants business operations previously conducted within the affected Premises to be carried on from an alternative location.

5.4    Security. Landlord shall provide on-site security for the Building and Project seven (7) days per week, twenty-four (24) hours per day,
including such equipment, personnel, procedures and systems as Landlord shall determine in its sole, subjective discretion, provided that Landlord reserves the right to change the type and level



16



---

of security at the Building and Project at any time in Landlords sole, subjective discretion so long as the type and level of security is generally
consistent with other comparable Class-A building in the Territory. Notwithstanding the foregoing, in no event will Landlord be liable to Tenant, and Tenant hereby waives any claim against Landlord, for (a) any entry of third parties into the
Premises, the Building and/or the Project; (b) any damage or injury to persons or property; or (c) any loss of property in or about the Premises, the Building and/or the Project, if the subject event described in the foregoing
clause (a), (b) or (c) occurs as a result of any unauthorized or criminal acts of third parties, regardless of any action, inaction, failure, breakdown, malfunction or insufficiency of the security services provided by
Landlord.

6. REPAIRS.

6.1    Condition of Premises. Tenant acknowledges that, except as otherwise expressly set forth in this Lease, neither Landlord nor any agent of Landlord has
made any representation or warranty with respect to the Premises, the Building, or the Project or their condition, or with respect to the suitability thereof for the conduct of Tenants business. Landlord does hereby represent and warrant to
Tenant that as of the date hereof and as of the date that Landlord delivers possession of the Premises to Tenant, the Premises, the Building and the Common Areas are and shall be in material compliance with all applicable laws and with the Operation
and Reciprocal Easement Agreement referred to in Section 1.3(f) above. Subject to the provisions of Exhibit D, the taking of possession of the Premises by Tenant shall conclusively establish that the Project, the
Premises, the Leasehold Improvements therein, the Building and the Common Areas were at such time complete and in good, sanitary and satisfactory condition and repair with all work required to be performed by Landlord, if any, pursuant to
Exhibit D completed and without any obligation on Landlords part to make any alterations, upgrades or improvements thereto, except as provided in Exhibit D. To the extent assignable, Landlord
shall assign any contractor warranties relating to the Base Building Improvements to Tenant effective as of the Commencement Date.

6.2    Tenants Repair and Notice Obligations. Except for Landlords obligations specifically set forth in Sections 6.1, 6.3, 10.2 and 12.2 hereof, Tenant shall at all times and at Tenants
sole cost and expense, keep, maintain, repair and preserve the Premises and all Leasehold Improvements, Tenant Changes (as defined in Section 7.1 below), and any alterations, additions and property therein in first-class condition and repair,
reasonable wear and tear excepted. Such maintenance and repairs shall be performed with due diligence, lien-free and in a first-class workmanlike manner, by such contractor(s) selected by Tenant and approved by Landlord, which approval shall not be
unreasonably withheld or delayed. Furthermore, Tenant will notify Landlord promptly after Tenant learns of (i) any fire or other casualty in the Premises; (ii) any damage to or defect in the Premises, including the fixtures and equipment
in the Premises, for the repair of which Landlord might be responsible; and (iii) any damage to or defect in any parts or appurtenances of the sanitary, electrical, heating, air conditioning, elevator or other systems located in or passing
through the Premises. Except as otherwise expressly provided in this Lease, Landlord shall have no obligation to alter, remodel, improve, repair, renovate, redecorate or paint all or any part of the Premises.

6.3    Landlords Repair Obligations. Notwithstanding the provisions of Section 6.2
above to the contrary, Landlord shall, as part of the Operating Expenses, repair and maintain in a first class condition (a) the Buildings shell and other structural portions of the Building (including the roof and foundations) (the
Building Structure), (b) the basic plumbing, heating, ventilating, air conditioning, sprinkler and electrical systems within the Buildings core and otherwise installed or furnished by Landlord as part of the Base
Building Improvements (as defined in Exhibit D) (the Building Systems) and (c) the Common Areas. Notwithstanding the foregoing but subject to the provisions of Section 9.3, to the extent such
maintenance or repairs are required as a result of any act, neglect, fault or omission of Tenant or any of Tenants agents, employees, contractors, licensees or invitees, Tenant shall pay to Landlord, as Additional Rent, the reasonable and
actual costs of such maintenance and repairs, together with an administrative fee equal to five percent (5%) of the cost of such maintenance and repair to cover Landlords overhead.



17



---

6.4    Failure to Maintain Premises. If
Tenant fails to perform any of its obligations under Section 6.2 above, then, at any time following ten (10) days after the date on which Landlord makes written demand on Tenant to effect such repair and maintenance (and at any time
without notice in the event of an emergency), Landlord may perform such obligations and Tenant will pay as Rent to Landlord the cost of such performance, including an administrative fee equal to five percent (5%) of the cost of such maintenance
and repair to cover Landlords overhead, within thirty (30) days after the date of Landlords invoice. For purposes of performing such obligations, or to inspect the Premises, Landlord may enter the Premises upon not less than
24 hours telephonic or electronic mail notice to Tenant (except in cases of actual or suspected emergency, in which case no prior notice will be required) without liability to Tenant for any loss or damage incurred as a result of such
entry, provided Landlord will use commercially reasonable efforts to effect such repair and/or maintenance in a manner that minimizes disruption to Tenants business or its use of the Premises.

6.5    Tenants Repair Rights. If Landlord fails to complete any repair or maintenance
that Landlord is required to complete under this Lease within thirty (30) days after receipt of written notice from Tenant, or if more than thirty (30) days is necessary to complete the repair or maintenance and Landlord fails to commence
the repair or maintenance within such 30-day period and does not diligently pursue the completion of the same, and such repair or maintenance does not involve the Building Structure or Building Systems or Common Areas (it being understood that
Tenant shall have no right to perform any repairs to such areas notwithstanding anything to the contrary contained in this Lease), then Tenant shall give Landlord written notice specifying that Tenant intends to perform such required action, and if
Landlord, within an additional five (5)-day period following receipt of Tenants notice, fails to commence the performance of the required action and diligently pursue the same to completion, Tenant shall have the right to perform the
required action and shall be entitled to reimbursement by Landlord of Tenants actual and reasonable costs and expenses in taking such action. In the event Tenant takes such action as permitted hereunder, Tenant shall use only those contractors
used by Landlord in the Building (based upon Landlords list of approved contractors which shall be provided to Tenant within two (2) business days after Tenants request for same) for similar work unless such contractors are
unwilling or unable to perform such work in a timely manner at reasonably competitive rates (vis-à-vis other qualified contractors), in which event Tenant may utilize the services of any other qualified contractor reasonably approved by
Landlord (Landlords failure to respond to Tenants request for approval of a contractor within two (2) business days shall be deemed approval) which normally and regularly performs similar work in comparable buildings located in the
vicinity of the Project. Tenant shall require the contractors to provide evidence of reasonable insurance coverage before performing any maintenance and/or repair, and shall ensure that Landlord and Landlords lender(s) (and any other parties
reasonably designated by Landlord) is named as an additional insured on such insurance policy or policies. Tenant shall not be entitled to reimbursement until Tenant has provided Landlord with reasonable documentation that it has paid for such
repair and/or maintenance (including, without limitation, invoices and paid receipts) and has provided Landlord with valid lien releases, if applicable. Landlord shall reimburse Tenant within thirty (30) days after receipt of the foregoing
documentation. If Landlord fails to reimburse Tenant within sixty (60) days after receipt of the foregoing documentation, such amounts shall bear interest at the Interest Rate until Tenant receives such reimbursement. Notwithstanding the
foregoing, if Landlord delivers to Tenant within thirty (30) days after receipt of Tenants invoice and other required documentation, a written objection to the payment of such invoice, setting forth with reasonable particularity
Landlords reasons for its claim that such action did not have to be taken by Landlord pursuant to the terms of this Lease or that the charges are excessive (in which case Landlord shall pay the amount it contends is not excessive), then Tenant
may proceed to claim a default by Landlord under this Lease, provided that Tenants sole remedy against Landlord shall be an action for actual damages and in no event shall Tenant have any right of deduction or offset against any of
Tenants obligations under this Lease.



18



---

7. ALTERATIONS.

7.1    Tenant Changes; Conditions. After installation of the Leasehold Improvements for the
Premises pursuant to Exhibit D, Tenant may, at its sole cost and expense, make alterations, additions, improvements and decorations to the Premises (collectively, Tenant Changes) subject to and upon the
following terms and conditions:

(a) Notwithstanding any provision in this Section 7 to the contrary, Tenant is
absolutely prohibited from making any alterations, additions, improvements or decorations which: (i) affect any area outside the Premises; (ii) affect the Building Structure or the Building Systems, or the proper functioning thereof, or
Landlords access thereto; (iii) affect the outside appearance, character or use of the Project, the Building or the Common Areas; (iv) weaken or impair the structural strength of the Building Structure; (v) in the reasonable
opinion of Landlord, lessen the value of the Project or Building; or (vi) will violate or require a change in any occupancy certificate applicable to the Premises.

(b) Before proceeding with any Tenant Change which is not otherwise prohibited in Section 7.1(a) above, Tenant must first obtain
Landlords written approval thereof (including approval of all plans, specifications and working drawings for such Tenant Change), which approval shall not be unreasonably withheld or delayed. However, Landlords prior approval shall not
be required for any Tenant Change (i) which, when combined with all of Tenants other Tenant Changes over a twelve (12)-month period do not, in the aggregate, cost more than Twenty-Five Thousand Dollars ($25,000.00) or
constitutes a cosmetic Tenant Change (such as painting, carpentry, wall covering, hanging pictures) (a Cosmetic Change); (ii) provided that Tenant delivers to Landlord final plans, specifications and working drawings for
such Tenant Change at least ten (10) days prior to commencement of the work thereof except for Cosmetic Changes; and (iii) further provided that Tenant and such Tenant Change otherwise satisfy all other conditions set forth in this
Section 7.1. Landlords failure to disapprove the Tenant Changes in accordance with this Section within ten (10) days after Landlords receipt of Tenants approval request shall constitute Landlords disapproval of the
Tenant Changes.

(c) After Landlord has approved the Tenant Changes and the plans, specifications and working drawings
therefor, Tenant shall: (i) enter into an agreement for the performance of such Tenant Changes with such contractors and subcontractors selected by Tenant and approved by Landlord, which approval shall not be unreasonably withheld, conditioned
or delayed; (ii) before proceeding with any Tenant Change, provide Landlord with ten (10) days prior written notice thereof; and (iii) pay to Landlord, within fifteen (15) days after written demand, the costs of any
increased insurance premiums incurred by Landlord specifically attributable to such Tenant Changes in the fire and extended coverage insurance obtained by Landlord pursuant to Section 9.1 below. However, Landlord shall be required to include
the Tenant Changes under such insurance only to the extent such insurance is actually obtained by Landlord and such Tenant Changes are insurable under such insurance; if such Tenant Changes are not or cannot be included in Landlords insurance,
Landlord shall notify Tenant and Tenant shall insure the Tenant Changes under its personal property insurance pursuant to Section 9.2 below. In addition, before proceeding with any Tenant Change, Tenants contractors shall obtain, on
behalf of Tenant and at Tenants sole cost and expense, all necessary governmental permits and approvals for the commencement of such Tenant Change.

(d) Tenant shall pay to Landlord, as additional rent, the reasonable and actual out of pocket costs of Landlords engineers and other consultants for review of all plans, specifications and working drawings for
the Tenant Changes, within thirty (30) days after Tenants receipt of invoices either from Landlord or such consultants.

(e) All Tenant Changes shall be performed: (i) in accordance with the approved plans, specifications and working drawings; (ii) lien-free and in a first-class and workmanlike manner; (iii) in compliance with all laws, rules,
and regulations of all governmental agencies and authorities; (iv) in such a manner so as not to unreasonably interfere with the occupancy of any other tenant in the Project or Building, nor impose any additional expense upon nor unreasonably
delay Landlord in the maintenance and operation of the Project or Building; and (v) at such times, in such manner and subject to the Rules and Regulations.



19



---

(f) Throughout the performance of the Tenant Changes, Tenant shall obtain, or cause its
contractors to obtain, workers compensation insurance and general liability insurance in compliance with the provisions of Section 9.2 of this Lease.

(g) Any and all alterations that are Telecom Equipment (as defined in Section 26.1(a) below) will also be governed by the terms and conditions of Section 26, and if there is any conflict between
the requirements of this Section 7.1 and those of Section 26 with respect to Telecom Equipment, Section 26 will govern.

(h) Removal of Tenant Changes and Leasehold Improvements. All Tenant Changes and the Leasehold Improvements in the Premises (whether installed or paid for by Landlord or Tenant), shall become the property of Landlord
and shall remain upon and be surrendered with the Premises at the end of the Term of this Lease. Landlords consent to the Leasehold Improvements and Tenant Changes shall relieve Tenant of any obligation to remove such Leasehold Improvements
and/or Tenant Changes at the expiration or sooner termination of this Lease, unless, with respect to Tenant Changes only, at the time Landlord consents to such Tenant Changes, Landlord indicates that it will require removal of such Tenant Changes on
the expiration or sooner termination of this Lease. If Tenant so desires, Tenant may, prior to making any Tenant Changes (regardless of whether Landlords consent to such Tenant Changes is required), request Landlord to notify Tenant, in
writing, within ten (10) days following receipt of Tenants request, as to whether Landlord will require the removal of such Tenant Changes and restoration of the Premises to the condition which existed prior to the performance of any such
Tenant Changes, reasonable wear and tear excepted. If Landlord fails to respond to Tenants request, in writing, within such ten (10)-day period, Landlord shall be deemed to have elected to require that such Tenant Changes not be removed
and the Premises not be restored as of the expiration or sooner termination of the Term of this Lease. If Landlord requires Tenant to remove any such items as described above, Tenant shall, at its sole cost, remove the identified items on or before
the expiration or sooner termination of this Lease and repair any damage to the Premises caused by such removal reasonable wear and tear excepted (or, at Landlords option, shall pay to Landlord all of Landlords costs of such removal and
repair). Notwithstanding anything in this Lease to the contrary, under no circumstances will Tenant be required to remove any Leasehold Improvement performed as the initial build-out pursuant to Exhibit D, or to repair,
replace or paint wall or floor coverings or patch small holes in the walls caused by wall coverings (e.g., picture frames) at the Expiration Date or sooner termination date of this Lease (Surrender Condition Qualifications);
provided, however, that notwithstanding the foregoing, Tenant shall, except to the extent that Landlord elects otherwise by written notice to Tenant, be required to remove any generators (including Tenants Back-Up Systems (as defined in
Section 30 below)), satellite equipment (including the Satellite System (as defined in Section 31 below)) and ATMs (including the ATM and ATM Equipment (as those terms are defined in Section 32 below)) and other similar type equipment
on or before the Expiration Date or sooner termination date of this Lease and shall restore the Premises and/or Building to the condition which existed prior to the installation of such items or to the condition that would have existed if such item
had not been included in the initial build-out of the Building or Premises, reasonable wear and tear excepted. Notwithstanding the foregoing, Tenant shall not be required to remove Tenants HVAC Units (as defined in Section 30 below) so
long as such equipment is in good operating condition; otherwise Landlord may elect to require Tenant to remove such equipment at the Expiration Date or earlier termination of this Lease.

Subject to Landlords prior written approval (which will not be unreasonably withheld) and Landlords right to impose reasonable
requirements as to the contractor as provided in this Section 7, Tenant shall have the non-exclusive right, subject to availability, to the reasonable use of the Buildings roof, shafts, risers and conduits between Tenants Premises
and other parts of the Buildings roof, shafts, risers and conduits between Tenants Premises and other parts of the Building for the sole purpose of installing cabling for communications, data processing, Tenants HVAC Units, the
Satellite System and Tenants Back-Up System.

7.2    Tenants Failure to
Remove. Subject to the Surrender Condition Qualifications, if Tenant fails to remove by the expiration or sooner termination of this Lease substantially all of its personal property, or any items of Tenant Changes identified by Landlord for
removal pursuant to Section 7.1 above, Landlord may, after



20



---

Tenants continued failure after ten (10) days written notice to Tenant, and at its option, treat such failure as a holdover pursuant to
Section 15.2 below, and/or may (without liability to Tenant for loss thereof), at Tenants sole cost and in addition to Landlords other rights and remedies under this Lease, at law or in equity: (a) remove and store such items;
and/or (b) upon an additional ten (10) days prior notice to Tenant, sell all or any such items at private or public sale for such price as Landlord may obtain. Landlord shall apply the proceeds of any such sale to any amounts due to
Landlord under this Lease from Tenant (including Landlords attorneys fees and other costs incurred in the removal, storage and/or sale of such items), with any remainder to be paid to Tenant.

7.3    Alterations by Landlord. Landlord may from time to time make repairs, changes,
additions and improvements to the Project, the Building, Common Areas and those Project and Building Systems necessary to provide the services described in Section 5, and for such purposes, Landlord may enter the Premises upon not less than
twenty-four (24) hours prior telephonic notice to Tenant (except in cases of actual or suspected emergency, in which case no prior notice will be required) without liability to Tenant for any loss or damage incurred as a result of
such entry, provided that in doing so Landlord will use commercially reasonable efforts to not disturb or unreasonably interfere with Tenants use of the Premises and operation of its business, will repair any damage to the Premises caused by
such entry, and shall use commercially reasonable efforts to comply with all applicable Laws regarding bank customer privacy and bank security of which Landlord is actually aware. No permanent change, addition or improvement made by Landlord will
materially impair access to the Premises.

8. LIENS. Tenant agrees to pay before delinquency all
costs for work, services or materials furnished to Tenant for the Premises, the nonpayment of which could result in any lien against the Project or Building. Tenant will keep title to the Project and Building free and clear of any such lien. Tenant
will immediately notify Landlord of the filing of any such lien or any pending claims or proceedings relating to any such lien and will protect, defend, indemnify and hold Landlord harmless from and against all loss, damages and expenses (including
reasonable attorneys fees) suffered or incurred by Landlord as a result of such lien, claims and proceedings. Tenant shall, at Landlords request, provide Landlord with enforceable, conditional and final lien releases (and other evidence
reasonably requested by Landlord to demonstrate protection from liens) from all persons furnishing labor and/or materials with respect to the Premises. Landlord shall have the right at all reasonable times to post on the Premises and record any
notices of non-responsibility which it deems necessary for protection from such liens. In case any such lien attaches, Tenant agrees to cause it to be immediately released and removed of record (failing which Landlord may do so at Tenants sole
expense), unless Tenant has a good faith dispute as to such lien in which case Tenant may contest such lien by appropriate proceedings so long as Tenant deposits with Landlord a bond or other security in an amount reasonably acceptable to Landlord
which may be used by Landlord to release such lien if Tenants contest is abandoned or unsuccessful. Upon final determination of any permitted contest, Tenant will immediately pay any judgment rendered and cause the lien to be released. If
Tenant fails to cause such lien to be so released or bonded within ten (10) days after filing thereof, such failure shall be deemed a material breach by Tenant under this Lease, and Landlord may, without waiving its rights and remedies based on
such breach, and without releasing Tenant from any of its obligations, cause such lien to be released by any means it shall deem proper, including payment in satisfaction of the claim giving rise to such lien. Tenant shall pay to Landlord within
fifteen (15) days after receipt of invoice from Landlord, any sum paid by Landlord to remove such liens, together with interest at the Interest Rate from the date of such payment by Landlord.



|9. | INSURANCE.
|-- | ----------

9.1    Landlords Insurance. During the Term, Landlord will provide and keep in force the following insurance:

(a) comprehensive or commercial general liability insurance relating to Landlords operation of the Project, including coverage for
personal and bodily injury and death, and damage to others property;

(b) all risk property
insurance relating to the Project for the full replacement value, including, without limitation, against loss or damage due to fire and other casualties covered within the classification



21



---

of fire and extended coverage, vandalism coverage and malicious mischief, sprinkler leakage, water damage and special extended coverage (but excluding
Tenants fixtures, furnishings, equipment, personal property, documents, files and work products and all Leasehold Improvements in the Premises that were paid for by Tenant; for purposes of this Section 9.1(b) and Section 9.2(d)
below, any Leasehold Improvements paid for with an allowance provided by Landlord, regardless of whether a portion of the Base Rent is intended to reimburse Landlord for such allowance, will be deemed paid for by Landlord);

(c) loss of rental income insurance or loss of insurable gross profits commonly insured against by reasonably prudent landlords of
comparable class office buildings in the Territory; and

(d) such other insurance (including boiler and machinery insurance)
as Landlord reasonably elects to obtain or any Project or Building mortgagee requires.

Insurance effected by Landlord under this
Section 9.1 will be in amounts which Landlord from time to time reasonably determines sufficient or any Project or Building mortgagee requires; will be subject to such deductibles and exclusions as Landlord reasonably determines are
commercially reasonable; and will otherwise be on such terms and conditions as Landlord from time to time reasonably determines sufficient; provided however, that the coverage and amounts of insurance and amount of deductibles carried by Landlord
shall substantially be comparable to the coverage and amounts of insurance which are carried by reasonably prudent landlords of first-class comparable office buildings in the Territory. Landlord shall also carry Workers Compensation and
Employers Liability Coverage to the extent required by applicable law.

9.2    Tenants Insurance. During the Term, Tenant will provide, pay for and maintain in full force and effect, the insurance outlined herein, covering claims arising
out of or in connection with the use, occupancy or maintenance of the Premises, and all areas appurtenant thereto, by Tenant, its agents, representatives, employees or contractors. Tenant will contractually require its contractors and any
subcontractors to obtain the types of insurance outlined herein, and upon Landlords request, Tenant will cause such contractors and/or subcontractors to execute documentation satisfactory to Landlord, whereby each such contractor and
subcontractor will agree to maintain such types of insurance with limits reasonably required by Landlord during the entire period that they conduct any work in the Project, and to provide proof of such insurance (in a form reasonably satisfactory to
Landlord).

(a) Commercial General Liability. Tenant will maintain commercial general liability insurance covering
liability arising out of the use, occupancy or maintenance of the Premises on an occurrence basis against claims for bodily injury and property damage (including loss of use), personal injury and advertising injury. Such insurance will provide
minimum limits and coverage as follows:

(i) Minimum Limits.

(A) $1,000,000 Each Occurrence (Combined Single Limit Bodily Injury and Property Damage).

(B) $2,000,000 General Aggregate.

(C) $2,000,000 Products / Completed Operations Aggregate.

(D) $300,000 Fire Damage.

(ii) Coverages.

(A) 1986 (or later) ISO Commercial General Liability Form (Occurrence Form).

(B)
Additional Insured: Landlord, its managers, members, partners, officers and directors, employees, agents, subsidiaries, affiliates and Property Manager.

(C) Waiver of Subrogation in favor of Landlord and Property Manager.



22



---

(b) Automobile Liability. Tenant will maintain business auto liability covering
liability arising out of any auto (including owned, hired and non-owned autos).

(i) Minimum Limits. $1,000,000 Combined
Single Limit for each accident.

(ii) Coverages.

(A) Additional Insureds. Landlord, its managers, members, partners, officers and directors, employees, agents, subsidiaries, affiliates
and Property Manager.

(B) Waiver of Subrogation in favor of Landlord and Property Manager.

(c) Workers Compensation. Tenant will maintain workers compensation and employers liability insurance.

(i) Minimum Limits.

(A) Workers Compensation: Statutory Limits.

(B) Employers Liability:

(1) Bodily Injury for Each Accident  $500,000.

(2) Bodily Injury by Disease for Each Employee  $500,000.

(3) Bodily Injury Disease Aggregate  $500,000.

(ii) Coverages. Waiver of Subrogation in favor of Landlord and Property Manager.

(d) Personal Property. Tenant will maintain property insurance covering all personal property and equipment (including, but not
limited to furnishings, fixtures, inventory and stock in trade paid for by Tenant) in the Premises as well as the Tenant Changes (to the extent required under Section 7.1(c) above, all on a full replacement cost basis in amounts sufficient to
prevent Tenant from becoming a coinsurer and insuring against Special Causes of Loss, including an amount of no less than $1,000 for money and securities (inside and outside of the Premises) and vandalism and malicious mischief.

(e) Umbrella/Excess Liability. Tenant will maintain umbrella/excess liability insurance as shown below. The insurance will be on an
occurrence basis in excess of the underlying insurance described in Sections 9.2(a), (b) and (c)(i)(B) and will be at least as broad as each and every one of the underlying policies.

(i) Minimum Limits.

(A) $5,000,000 per Occurrence.

(B) $5,000,000 Aggregate.

(ii) Coverages.

(A) Additional Insured. Landlord, its managers, members, partners, officers and directors, employees, agents, subsidiaries, affiliates and Property Manager.

(B) Pay on Behalf of Wording.

(C) Concurrency of Effective Dates with primary insurance.

(D) Aggregates: Follow Form Primary.

(E) Drop Down Feature.

(F) Waiver of Subrogation in favor of Landlord and Property
Manager.

(f) Business Income. Tenant will maintain business income and extra expense coverage for no less than
six (6) months of income and expenses, including a waiver of subrogation endorsement in favor of Landlord and Property Manager.



23



---

(g) Other Insurance Provisions. Tenant will name, will cause its contractors and
subcontractors to name, and will cause the applicable contracts with such contractors and subcontractors to provide that each such contractor and subcontractor will name, Landlord, Landlords managers, members, partners, officers and directors,
subsidiaries, affiliates, employees, agents and Property Manager as additional insureds with respect to liability arising out of Tenants use, occupancy, or maintenance of the Premises or activities performed thereon, on all liability policies
carried by Tenant and/or Tenants contractors and subcontractors. Tenants insurance will be primary and non-contributory insurance over any insurance carried by Landlord. Tenants Workers Compensation insurer will agree to
waive all rights of subrogation against Landlord and Property Manager, its managers, members, partners, officers and directors, employees, agents, subsidiaries and affiliates for losses arising from work or activities performed by Tenant. All
liability insurance policies carried by Tenant will include provisions for contractual liability coverage insuring Tenant for the performance of its indemnity obligations set forth herein. It is expressly understood and agreed that the coverages
required represent Landlords minimum requirements and such are not to be construed to void or limit Tenants indemnity obligations contained in this Lease. Neither (i) the insolvency, bankruptcy or failure of any insurance company
covering Tenant, (ii) the failure of any insurance company to pay claims occurring nor (iii) any exclusion from or insufficiency of coverage will be held to affect, negate or waive any of Tenants indemnity obligations under
Sections 4.3, 4.4(d), 7.1, 8, 11.3, 23 or 26.5 hereof or any other provision of this Lease. The amount of liability insurance under insurance policies maintained by Tenant will not be reduced by the existence of insurance coverage under
policies separately maintained by Landlord. Tenant will be solely responsible for any premiums, assessments, penalties, deductible assumptions, retentions, audits, retrospective adjustments or any other kind of payment due under its policies.
Tenants occupancy of the Premises without delivering the certificates and/or other evidence of insurance, will not constitute a waiver of Tenants obligations to provide the required coverages. If Tenant provides to Landlord a certificate
that does not evidence the coverages required herein, or that is faulty in any respect, Landlords acceptance of such certificate will not constitute a waiver of Tenants obligations to provide the proper insurance.

(h) Proof of Insurance. Prior to execution of this Lease, Tenant will furnish Property Manager with certificates of insurance
evidencing the coverage outlined above. Insurance is to be placed with insurers with a Bests rating of no less than A IX. No such policy will be cancelable or modified except after 30 days written notice to Property Manager. Tenant
will maintain all of the foregoing insurance coverages in full force and effect until the expiration or earlier termination of this Lease.

9.3    Waiver of Subrogation. Landlord and Tenant agree that all insurance required to be carried under Sections 9.1(b), (c), (d) and 9.2(d) and other property
damage insurance which may be carried by either of them will be endorsed with a clause providing that any release from liability of, or waiver of claim for, recovery from the other party entered into in writing by the insured thereunder prior to any
loss or damage will not affect the validity of such policy or the right of the insured to recover under such policy, and providing further that the insurer waives all rights of subrogation which such insurer might have against the other
party (and, when the other party is Landlord, such waiver will apply to Property Manager as well). Without limiting any release or waiver of liability or recovery set forth elsewhere in this Lease, and notwithstanding anything in
this Lease which may appear to be to the contrary, each of the parties hereto waives all claims for recovery from the other party for any loss or damage to any of its property insured (or required by the terms of this Lease to be insured) under
valid and collectible insurance policies to the extent of any recovery collectible (or would have been collectible if the insurance required under this Lease had been maintained) under such insurance policies, provided that the foregoing waiver will
not apply to any amount that is not reimbursable or paid by the damaged partys insurer because of the deductible or self-insured retention portion of the damaged partys insurance coverage. Notwithstanding the foregoing or anything
contained in this Lease to the contrary, any release or any waiver of claims will not be operative, nor will the foregoing endorsements be required, in any case in which the effect of such release or waiver is to invalidate insurance coverage or
invalidate the right of the insured to recover thereunder or to increase the cost thereof (provided that in the case of increased cost, the other party will have the right, within (ten) 10 days following written notice, to pay such increased
cost in order to keep such release or waiver in full force and effect).



24



---

10. DAMAGE OR DESTRUCTION.

10.1    Landlords Rights and Obligations. In the event the Premises or any part of the
Building is damaged by fire or other casualty to an extent not exceeding twenty-five percent (25%) of the full replacement cost thereof (exclusive of the Leasehold Improvements and Tenant Changes), and Landlords contractor reasonably
estimates in a writing delivered to the parties that the damage thereto is such that the Building and/or Premises may be repaired, reconstructed or restored to substantially its condition immediately prior to such damage within one hundred
eighty (180) days from the date of such casualty and Landlord will or would receive insurance proceeds sufficient to cover the costs of such repairs, reconstruction and restoration (less any insurance deductible Landlord must pay or incur in
connection therewith) had Landlord carried the insurance required to be carried by Landlord pursuant to this Lease (including proceeds from Tenant and/or Tenants insurance which Tenant is required to deliver to Landlord pursuant to
Section 10.2 below), or should Landlord be a self-insurer for such casualty and such casualty would have been covered by the insurance required under this Lease had Landlord not elected to self-insure for such risk, then Landlord shall commence
and proceed diligently with the work of repair, reconstruction and restoration (including the Leasehold Improvements and any Tenant Changes to the extent such Tenant Changes are insured by Landlord pursuant to Section 7.1(c) above) and this
Lease shall continue in full force and effect. If, however, the Premises or any other part(s) of such Building is damaged to an extent exceeding twenty-five percent (25%) of the full replacement cost thereof, or Landlords contractor
reasonably estimates that such work of repair, reconstruction and restoration will require longer than one hundred eighty (180) days to complete, or Landlord will not receive insurance proceeds even though Landlord carried the insurance
required to be carried by Landlord pursuant to this Lease (and/or proceeds from Tenant, as applicable) sufficient to cover the costs of such repairs, reconstruction and restoration (less any insurance deductible Landlord must pay or incur in
connection therewith), then Landlord may elect to either: (a) repair, reconstruct and restore the portion of the Building and Premises damaged by such casualty (including the Leasehold Improvements and Tenant Changes insured by Landlord
pursuant to Section 7.1(c) above), in which case this Lease shall continue in full force and effect; or (b) terminate this Lease by giving written notice to Tenant within sixty (60) days after Landlord receives notice of the
occurrence of any such casualty, and such termination shall be effective as of the date which is thirty (30) days after Tenants receipt of Landlords election to so terminate.

10.2    Tenants Costs and Insurance Proceeds. In the event of any damage or destruction
of all or any part of the Premises, Tenant shall promptly: (a) notify Landlord thereof; and (b) deliver to Landlord all insurance proceeds received by Tenant with respect to the Leasehold Improvements in the Premises but only to the extent
that such items are not covered by Landlords property insurance obtained by Landlord pursuant to Section 9.1 above (excluding proceeds for Tenants furniture and other personal property), whether or not this Lease is terminated as
permitted in this Section 10, and Tenant hereby assigns to Landlord all rights to receive such insurance proceeds. If, due to Tenants failure to obtain insurance for any Tenant Changes which Tenant is required to insure pursuant to
Sections 7.1(c) and/or 9.2(d) hereof), Tenant fails to receive insurance proceeds covering the full replacement cost of such Tenant Changes which are damaged, Tenant shall be deemed to have self-insured the replacement cost of such Tenant
Changes. Upon any damage or destruction to any Tenant Changes and to the extent that Landlord is required to or elects to reconstruct same for Tenants use as provided in this Lease, Tenant shall pay to Landlord the full replacement cost of
such items, less any insurance proceeds actually received by Landlord from Landlords or Tenants insurance with respect to such items within thirty (30) days after receipt of written demand from Landlord.

10.3    Abatement of Rent. In the event that as a result of any such damage, repair,
reconstruction and/or restoration of the Premises or the Building, Tenant is prevented from using, and does not use, the Premises or any portion thereof for the Eligibility Period, then the Rent shall be abated during the period after the date
Tenant can no longer use the Premises or any portion thereof and throughout such period that Tenant continues to be so prevented from using and does not use the Premises or portion thereof, in the proportion that the Rentable Square Feet of the
portion of the Premises that Tenant is prevented from using, and does not use, bears to the total Rentable Square Feet of the Premises. Notwithstanding the foregoing but subject to the provisions of Section 9.3, if the damage is due to the
negligence or willful misconduct of Tenant or any Tenant Parties, there shall be no



25



---

abatement of Rent. However, in the event that Tenant is prevented from using and does not use any portion of the Premises and the remaining portion of the
Premises is not sufficient to allow Tenant to effectively conduct its business therein, and if Tenant does not conduct its business from such remaining portion, then for such time that Tenant is so prevented from effectively conducting its business
therein, the Rent for the entire Premises shall be abated; provided, however, if Tenant reoccupies and conducts its business from any portion of the Premises during such period, the Rent allocable to such reoccupied portion, based on the proportion
that the Rental Square Feet of such reoccupied portion of the Premises bears to the total Rental Square Feet of the Premises, shall be payable by Tenant from the date Tenant reoccupies such space. If Tenants right to abatement occurs during a
free rent period which arises after the Commencement Date, Tenants free rent period shall be extended by the Overlap Period (i.e., the number of days that the abatement period overlapped the free rent period). Notwithstanding the
foregoing, Tenant shall not be deemed to be using the Premises for purposes of this Section 10.3 if Tenant is merely maintaining a skeleton crew within the affected Premises for such purposes as securing Tenants records and files,
forwarding telephone communications, correspondence and deliveries, and/or otherwise enabling those aspects of Tenants business operations previously conducted within the affected Premises to be carried on from an alternative location.

10.4    Inability to Complete. Notwithstanding anything to the contrary
contained in this Section 10 in the event Landlord is obligated or elects to repair, reconstruct and/or restore the damaged portion of the Building or Premises pursuant to Section 10.1 above, but is delayed from completing such repair,
reconstruction and/or restoration beyond the date which is six (6) months after the date estimated by Landlords contractor for completion thereof pursuant to Section 10.1 by reason of any causes beyond the reasonable control of
Landlord (including, without limitation, any acts of God, war, governmental restrictions, and delays caused by Tenant or any Tenant Parties), then either party may elect to terminate this Lease upon thirty (30) days prior written notice
to the other.

10.5    Damage Near End of Term. In addition to its termination
rights in Sections 10.1 and 10.4 above, Landlord or Tenant shall have the right to terminate this Lease if any damage to the Building or Premises occurs during the last twelve (12) months of the Term of this Lease and Landlords
contractor estimates in a writing delivered to the parties that the repair, reconstruction or restoration of such damage cannot be completed within the earlier of (a) the scheduled expiration date of the Lease Term, or (b) sixty (60)
days after the date of such casualty. Notwithstanding the foregoing, if Tenant exercises any remaining right to extend the term of this Lease with fifteen (15) days after receipt of notice from Landlord that Landlord is contemplating
terminating this Lease pursuant to this Section 10.5, then neither Landlord nor Tenant shall have the right to terminate this Lease pursuant to this Section 10.5 as a result of such damage.

10.6    Waiver of Other Termination Rights. The provisions of California Civil Code
Section 1932, Subsection 2, and Section 1933, Subsection 4 (and any successor statutes thereof permitting Tenant to terminate this Lease as a result of any damage or destruction) are hereby expressly waived by Tenant, and
Tenants only termination rights relating to damage to or destruction of the Premises shall be as set forth in Sections 
10.4 and 10.5 above.

11. WAIVERS AND INDEMNITIES

11.1    Tenants Waivers. Except to the extent caused by the willful or negligent act or
omission or breach of this Lease by Landlord or anyone for whom Landlord is legally responsible, Landlord and its Affiliates will not be liable or in any way responsible for, and Tenant waives all claims against Landlord and its Affiliates for, any
loss, injury or damage suffered by Tenant or others relating to (a) loss or theft of, or damage to, property of Tenant or others; (b) subject to Section 9.3, injury or damage to persons or property resulting from fire, explosion,
falling plaster, escaping steam or gas, electricity, water, rain or snow, or leaks from any part of the Building or Project or from any pipes, appliances or plumbing, or from dampness; or (c) damage caused by other tenants, occupants or persons
in the Premises or other premises in the Building or Project, or caused by the public or by construction of any private or public work.



26



---

11.2    Landlords Indemnity. Subject to
Sections 5.3, 5.4, 9.3 and 11.1 and to the limitation on Landlords liability set forth in Section 24, and except to the extent caused by the willful misconduct, negligent act or omission, or breach of this Lease by Tenant or anyone
for whom Tenant is legally responsible, to the fullest extent permitted by applicable Laws, Landlord will indemnify, defend and hold harmless Tenant, its officers, directors, subsidiaries, affiliates, employees, and agents from and against any and
all liability, loss, claims, demands, damages or expenses (including reasonable attorneys fees) due to or arising out of (i) any breach or default in the performance of any obligation on Landlords part to be performed under the
provisions of this Lease, or (ii) the negligence or intentional misconduct of Landlord or any of its agents, contractors, employees or anyone for whom Landlord is legally responsible. Landlords obligations under this Section 11.2
will survive the expiration or early termination of the Term.

11.3    Tenants
Indemnity. Subject to Section 9.3 and except to the extent caused by the willful misconduct or negligent act or omission or breach of this Lease by Landlord or anyone for whom Landlord is legally responsible, to the fullest extent
permitted by applicable Laws, Tenant will indemnify, defend and hold harmless Landlord, its managers, members, partners, officers, directors, subsidiaries, affiliates, employees and agents and Property Manager from and against any and all liability,
loss, claims, demands, damages or expenses (including reasonable attorneys fees) due to or arising out of Tenants use, maintenance and/or occupancy of the Premises or from the conduct of its business or from any activity, work or things
which may be permitted or suffered by Tenant in or about the Premises (including, without limitation, accidents or occurrences resulting in injury, death, property damage or theft) or any breach or default in the performance of any obligation on
Tenants part to be performed under the provisions of the Lease or arising from any negligence or intentional misconduct of Tenant or any of its agents, contractors, employees, invitees or anyone for whom Tenant is legally responsible.
Tenants obligations under this Section 11.3 will survive the expiration or early termination of the Term.

12.
CONDEMNATION.

12.1    Full Taking. If all or substantially all of
the Project, Building or Premises are taken for any public or quasi-public use under any applicable Laws or by right of eminent domain, or are sold to the condemning authority in lieu of condemnation, then this Lease will terminate as of the date
when the condemning authority takes physical possession of the Project, Building or Premises.

12.2    Partial Taking

(a) Landlords
Termination of Lease. If only part of the Project, Building or Premises is thus taken or sold, and if after such partial taking, in Landlords reasonable judgment, alteration or reconstruction is not economically justified, then Landlord
(whether or not the Premises are affected) may terminate this Lease by giving notice to Tenant within sixty (60) days after the taking.

(b) Effective Date of Termination. Termination by Landlord will be effective as of the date when physical possession of the applicable portion of the Project, Building or Premises is taken by the condemning
authority.

(c) Election to Continue Lease. If Landlord does not elect to terminate this Lease upon a partial taking
of a portion of the Premises, the Rent payable under this Lease will be diminished by an amount allocable to the portion of the Premises which was so taken or sold as reasonably determined by Landlord. If this Lease is not terminated upon a partial
taking of the Project, Building or Premises, Landlord will, at Landlords sole expense, promptly restore and reconstruct the Project, Building and Premises to substantially their former condition prior to the taking. However, Landlord will not
be required to spend for such restoration or reconstruction an amount in excess of the net amount received by Landlord as compensation or damages for the part of the Project, the Building or Premises so taken.

(d) Waiver. Tenant hereby waives any and all rights it might otherwise have pursuant to Section 1265.130 of the California
Code of Civil Procedure.



27



---

12.3    Awards. As between the parties to
this Lease, Landlord will be entitled to receive, and Tenant assigns to Landlord, all of the compensation awarded upon taking of any part or all of the Project, Building or Premises, including any award for the value of the unexpired Term. However,
Tenant may assert a claim in a separate proceeding against the condemning authority for any damages resulting from the taking of Tenants trade fixtures or personal property, or for moving expenses, business relocation expenses or damages to
Tenants business incurred as a result of such condemnation.

13. ASSIGNMENT AND SUBLETTING.

13.1    General. Assignment or encumbrance of all or any part of this Lease, and any
sublease of all or any part of the Premises, shall only be permitted, in conformance with the provisions of this Section 
13.

13.2    Restriction on Transfer. Subject to the provisions of
Sections 13.3, 13.4, 13.5 and 13.6, Tenant shall not, without the prior written consent of Landlord, which shall not be unreasonably withheld or delayed, assign or encumber this Lease or any interest herein or sublet the Premises or any part
thereof, or permit the use or occupancy of the Premises by any party other than Tenant (any such assignment, encumbrance, sublease or the like shall sometimes be referred to as a Transfer). Any Transfer without Landlords
consent (except for a Transfer pursuant to Section 13.6) shall constitute a Default by Tenant under this Lease, and in addition to all of Landlords other remedies at law, in equity or under this Lease, such Transfer shall be voidable at
Landlords election. For purposes of this Section 13 but subject to Section 13.6, below, if Tenant is a corporation, partnership or other entity, any transfer, assignment, encumbrance or hypothecation of fifty percent (50%) or
more (individually or in the aggregate) of any stock or other ownership interest in such entity, and/or any transfer, assignment, hypothecation or encumbrance of any controlling ownership or voting interest in such entity, shall be deemed an
assignment of this Lease and shall be subject to all of the restrictions and provisions contained in this Section 13. Notwithstanding the foregoing, the immediately preceding sentence shall not apply to any transfers of stock of Tenant if
Tenant is a corporation whose stock is held by more than one hundred fifty (150) owners and such stock is transferred over a recognized security exchange or over-the-counter market.

13.3    Landlords Options. If at any time or from time to time during the Term Tenant
desires to effect a Transfer (other than a Permitted Transfer, as defined in Section 13.6 below), Tenant shall deliver to Landlord written notice (Transfer Notice) setting forth the terms and provisions of the
proposed Transfer and the identity of the proposed assignee, sublessee or other transferee (sometimes referred to hereinafter as a Transferee). Tenant shall also deliver to Landlord with the Transfer Notice, a current financial
statement and financial statements for the preceding two (2) years of the Transferee (which have been certified or audited by an independent accounting firm, if such Transferee otherwise has obtained such a certification or audit and, if not,
tax returns for the preceding two years and financial statements certified by the chief financial officer of the Transferee), and such other information concerning the business background and financial condition of the proposed Transferee as
Landlord may reasonably request. Landlord will have the following options, which must be exercised, if at all, by notice given to Tenant within ten (10) business days after Landlords receipt of the Transfer Notice:

(a) Approve the proposed Transfer;

(b) Disapprove the Proposed Transfer; or

(c) Terminate this Lease, provided that Tenant may
withdraw the Transfer Notice within ten (10) business days after receipt of Landlords notice to terminate this Lease, in which case, Landlords termination notice shall be void and Tenant shall continue to lease the Premises in
accordance with all of the terms and conditions of this Lease. If Tenant does not elect to withdraw the Transfer Notice within the above ten (10) business-day period, this Lease will terminate on the last day of the month following the above
ten (10) business-day period described herein, and Tenant, upon such termination, will be released from any further liability under this Lease.



28



---

13.4    Additional Conditions; Excess Rent.
Landlords consent to any proposed Transfer may be given or withheld in accordance with the standards set forth in this Section 13, including, but not limited to the factors set forth in Section 13.5 below, which the parties agree are
reasonable restrictions and conditions pursuant to California Civil Code section 1995.250. If Landlord does not disapprove the proposed Transfer within the above 10 business-day period, Tenant shall deliver to Landlord a second notice
requesting Landlords consent, which second notice shall include, in bold, all caps and underlined lettering, a statement that if Landlord fails to disapprove the proposed Transfer within ten (10) business days following Landlords
receipt of such second notice, Landlord shall be deemed to have approved the proposed Transfer. If Landlord grants such approval (or is deemed to have granted such approval), Tenant may enter into the proposed Transfer with such proposed Transferee
subject to the following further conditions:

(a) the Transfer shall be on substantially the same terms set forth in the
Transfer Notice delivered to Landlord (if the terms have substantially changed, Tenant must submit a revised Transfer Notice to Landlord and Landlord shall have another ten (10) days after receipt thereof to exercise any of the options
described in Section 13.3 above;

(b) no Transfer shall be valid and no Transferee shall take possession of the
Premises until an executed counterpart of the assignment, sublease or other instrument affecting the Transfer has been delivered to Landlord the provides that the Transferee shall expressly assume all of Tenants obligations under this Lease
(or with respect to a sublease of a portion of the Premises or for a portion of the Term, assume all of Tenants obligations applicable to such portion);

(c) no Transferee shall have a further right to assign, encumber or sublet, except on the terms herein contained; and

(d) fifty percent (50%) of the amount by which any rent or other economic consideration received by Tenant as a result of such
Transfer exceeds, in the aggregate, (i) the total Rent which Tenant is obligated to pay Landlord under this Lease (prorated to reflect obligations allocable to any portion of the Premises subleased), plus (ii) any reasonable brokerage
commissions, tenant improvement costs, attorneys fees and moving costs actually paid by Tenant in connection with such Transfer, shall be paid to Landlord within fifteen (15) days after receipt thereof as additional rental under this
Lease, without affecting or reducing any other obligations of Tenant hereunder.

13.5    Reasonable Disapproval. Landlord and Tenant hereby acknowledge that Landlords disapproval of any proposed Transfer pursuant to Section 13.4 shall be deemed
reasonably withheld if based upon any reasonable factor, including, without limitation, any or all of the following factors: (a) the proposed Transfer would result in more than three (3) subleases of portions of the Premises being in
effect at any one time during the Term; (b) the proposed Transferee is an existing tenant of the Project or is presently negotiating with Landlord (unless Landlord cannot accommodate the space requirement of the proposed Transferee within a
reasonable time frame) for space in the Project; (c) the proposed Transferee is a governmental entity; (d) the use of the Premises by the Transferee (i) is not permitted by the use provisions in Section 4.1 hereof, or
(ii) violates any exclusive use granted by Landlord to another tenant in the Project; (e) the Transfer would likely result in a significant increase in the use of the parking areas or Common Areas by the Transferees employees or
visitors, and/or significantly increase the demand upon utilities and services to be provided by Landlord to the Premises; (f) the Transferee does not have the financial capability to fulfill the obligations imposed by the Transfer; or
(g) the Transferee is not, in Landlords reasonable opinion, of reputable or good character.

13.6    Permitted Transfers. Notwithstanding any provisions of this Section 13 to the contrary, Tenant may assign this Lease or sublet the Premises or any portion thereof
(without paying any fees or excess Rent to Landlord, and without requiring Landlords consent) to any corporation or other entity which Controls, is Controlled by, or is under common Control with Tenant, or to any corporation or other entity
resulting from a merger or consolidation with Tenant or Tenants Parent, or to any person or entity which acquires all or substantially all of the assets of Tenants business (collectively, Permitted Transfers), provided
that: (a) if an assignment, the assignee assumes, in full, the obligations of Tenant under this Lease (or if a sublease, the



29



---

sublessee of a portion of the Premises or Term assumes, in full, the obligations of Tenant with respect to such portion); (b) Tenant remains fully
liable under this Lease except in the event of a merger or consolidation pursuant to which Tenant is no longer a separate entity; (c) the use of the Premises under Section 4.1 of this Lease remains unchanged; and (d) such transaction
is not entered into as a subterfuge to avoid the restrictions and provisions of this Section 13. For purposes of this Section 13.6 and in Section 13.9, Control means the direct or indirect ownership of more than
fifty percent (50%) of the voting securities of an entity or possession of the right to vote more than fifty percent (50%) of the voting interest in the ordinary direction of the entitys affairs.

13.7    No Release. No Transfer shall release Tenant of Tenants obligations under this
Lease or alter the primary liability of Tenant to pay the rent and to perform all other obligations to be performed by Tenant hereunder. Landlord may require that any Transferee remit directly to Landlord on a monthly basis during such periods as
Tenant is in default under this Lease, all monies due Tenant by said Transferee. However, the acceptance of Rent by Landlord from any other person shall not be deemed to be a waiver by Landlord of any provision hereof. Consent by Landlord to one
Transfer shall not be deemed consent to any subsequent Transfer. In the event of default by any Transferee of Tenant or any successor of Tenant in the performance of any of the terms hereof, Landlord may proceed directly against Tenant without the
necessity of exhausting remedies against such Transferee or successor.

13.8    Administrative and Attorneys Fees. If Tenant requests the consent of Landlord to any Transfer, then Tenant shall, upon demand, pay Landlord a nonrefundable
administrative fee of One Thousand Dollars ($1,000.00) together with an amount equal to the costs incurred by Landlord in processing such consent (including, without limitation, reasonable attorneys fees). Acceptance of the administrative
fee shall in no event obligate Landlord to consent to any proposed Transfer.

13.9    Occupancy. Notwithstanding any contrary provision of this Section 13, Tenant shall have the right without the receipt of Landlords consent, but on prior
reasonable written notice to Landlord including the full legal name of the Permitted Occupant (defined below), to permit the occupancy of the Premises by an Affiliate of Tenant that is Controlled by, Controls, or under common Control with Tenant or
an unaffiliated third party that has a business relationship with Tenant (which business relationship is not created solely in order to allow occupancy of the Premises under this Section 13 and such occupancy is not a subterfuge by Tenant to
avoid its obligations under this Lease or the restriction on Transfers pursuant to this Section 13) (collectively, a Permitted Occupant). Any Permitted Occupant shall be subject to all of the terms and conditions of this
Lease and any default by a Permitted Occupant under this Lease shall be deemed to be a default by Tenant under this Lease. Tenant shall promptly supply Landlord with any documents or information reasonably requested by Landlord regarding any such
individuals or entities. Any occupancy permitted under this Section 13.9 shall not be deemed a Transfer under this Section 13. Notwithstanding the foregoing, no such occupancy shall relieve Tenant from any obligations or liability under
this Lease. All such occupants and their occupancy shall terminate immediately upon an event of Default by Tenant.

14.
PERSONAL PROPERTY.

14.1    Installation and Removal. Tenant may
install in the Premises its personal property (including Tenants usual trade fixtures) in a proper manner, provided that no such installation will interfere with or damage the, Building Structure or Building Systems and provided further, that
if such installation would require any change, addition or improvement to the Premises, such installation will be subject to Section 7.1. If no Default then exists, any such personal property installed in the Premises by Tenant (a) may be
removed from the Premises from time to time in the ordinary course of Tenants business or in the course of making any Tenant Changes permitted under Section 7.1, and (b) will be removed by Tenant at the end of the Term according to
Section 15.1. Tenant will promptly repair at its expense any damage to the Building and/or Project resulting from such installation or removal, reasonable wear and tear excepted.

14.2    Responsibility. Tenant will be solely responsible for all costs and expenses related
to personal property used or stored in the Premises. Tenant will pay any taxes or other governmental impositions levied upon



30



---

or assessed against such personal property, or upon Tenant for the ownership or use of such personal property, on or before the due date for payment, it
being understood that such personal property taxes or impositions are not included within the definition of Real Property Taxes and Assessments provided in this Lease. Tenant agrees that all personal property of whatever kind, including,
without limitation, inventory and/or goods stored at or about the Premises, Tenants trade fixtures, and Tenants interest in tenant improvements which may be at any time located in, on or about the Premises or the Building, whether owned
by Tenant or third parties, will be at the sole risk or at the risk of those claiming through Tenant, and that Landlord will not be liable for any damage to or loss of such property; except where such damage or loss arises out of Landlords or
Landlord Parties gross negligence or willful misconduct.

14.3    Landlords
Lien. In addition to any statutory landlords lien and in order to secure payment of all Rent becoming due from Tenant, and to secure payment of any damages or loss which Landlord may suffer by reason of Tenants failure to perform
any of its obligations under this Lease, Tenant grants to Landlord a security interest in and an express contractual lien upon all goods, wares, equipment, fixtures, furniture, improvements and other personal property of Tenant now or later situated
on the Premises and all proceeds thereof. Tenants personal property may not be removed from the Premises without Landlords consent at any time a Default exists or, except as provided in Section 14.1, until all of Tenants
obligations under this Lease have been fully complied with and performed. Upon the occurrence of a Default, in addition to any other available remedies, Landlord will have all the rights of a secured party under the California Commercial Code with
respect to the property covered by such security interest. Upon Landlords request, Tenant agrees to execute and deliver to Landlord such financing statements as may be required to perfect such security interest.

15. END OF TERM.

15.1    Surrender. Upon the expiration or other termination of the Term, Tenant will immediately vacate and surrender possession of the Premises in good order, repair and condition, except for ordinary wear and
tear. Upon the expiration or other termination of the Term, Tenant agrees, subject to the Surrender Condition Qualification as defined in Section 7.1(h), to remove (a) all Tenant Changes to the Premises, the removal of which Landlord
requested or approved according to Section 7.1(h) at the time Landlord consented to their installation, and (b) all of Tenants trade fixtures, office furniture, office equipment and other personal property. Tenant will pay Landlord
on demand the cost of repairing any damage to the Premises, Building and/or Project caused by the installation or removal of any such items, reasonable wear and tear excepted. Notwithstanding the foregoing, Tenant will be responsible for removing
all Telecom Equipment at the expiration or earlier termination of the Term in accordance with Section 26.9 below. If Tenant fails to surrender the Premises on the expiration or earlier termination of this Lease despite demand to do so by
Landlord (including upon the expiration of any subsequent month-to-month tenancy pursuant to Section 15.2 below), with such removal and repair obligations completed, then, in addition to Landlords rights and remedies under
Section 7.2 above and the other provisions of this Lease, Tenant shall indemnify, defend with counsel reasonably acceptable to Landlord and hold Landlord harmless from all loss or liability including, without limitation, any claims made by any
succeeding tenant based thereon, and any attorneys fees and other costs of legal proceedings. The foregoing indemnity shall survive the expiration or earlier termination of this Lease. Tenants obligations under this Section 15.1
will survive the expiration or early termination of this Lease and no surrender of possession of the Premises by Tenant will limit Tenants liability under this Lease. No act or thing done by Landlord or Landlords agents during the Term
of this Lease will be deemed an acceptance of a surrender of the Premises, unless in writing signed by Landlord. The delivery of the keys to an employee or agent of Landlord will not operate as a termination of this Lease or a surrender of the
Premises.

15.2Holding Over. Tenant understands that it does not
have the right to hold over at any time and Landlord may exercise any and all remedies at law or in equity to recover possession of the Premises, as well as any damages incurred by Landlord, due to Tenants failure to vacate the Premises and
deliver possession to Landlord as required by this Lease. If Tenant holds over after the Expiration Date with Landlords prior written consent, Tenant will be deemed to be a tenant from month-to-month, at a monthly Base Rent, payable in



31



---

advance, equal to one hundred twenty-five percent (125%) of the monthly Base Rent payable during the last year of the Term, and Tenant will be bound by
all of the other terms, covenants and agreements of this Lease as the same may apply to a month-to-month tenancy. If Tenant holds over after the Expiration Date without Landlords prior written consent, Tenant will be deemed a tenant at
sufferance, at a daily Base Rent, payable in advance, equal to one hundred fifty percent (150%) of the Base Rent per day payable during the last year of the Term, and Tenant will be bound by all of the other terms, covenants and agreements of
this Lease as the same may apply to a tenancy at sufferance.

16.ESTOPPEL CERTIFICATES. At
any time and from time to time (but on not less than ten (10) business days prior request by Landlord or Tenant as appropriate), Landlord or Tenant, as appropriate, will execute, acknowledge and deliver to the other a certificate
substantially in the form of Exhibit F attached hereto or such other form as may reasonably be required by Landlord or Tenant, Landlords lender or any prospective purchaser of all or any portion of the Project,
certifying any or all of the following: (a) the Commencement Date and Expiration Date; (b) that this Lease is unmodified and in full force and effect (or, if there have been modifications, that this Lease is in full force and effect, as
modified, and stating the date and nature of each modification); (c) the date, if any, through which Base Rent, Additional Rent and any other Rent payable have been paid; (d) that no default by Landlord or Tenant exists which has not been
cured, except as to defaults stated in such certificate; (e) that Tenant has no existing defenses or set-offs to enforcement of this Lease, except as specifically stated in such certificate; (f) provided such events have occurred, that
Tenant has accepted the Premises and that all improvements required to be made to the Premises by Landlord have been completed according to this Lease; (g) that, except as specifically stated in such certificate, Tenant, and only Tenant,
currently occupies the Premises; and (h) such other matters as may be reasonably requested. Any such certificate may be relied upon by Landlord or Tenant and any prospective purchaser or present or prospective mortgagee, deed of trust
beneficiary or ground lessor of all or a portion of the Building and/or Project or Tenant. Landlords or Tenants (as appropriate), failure to deliver such certificate within such time, and if such failure continues for another
five (5) business days after receipt of an additional notice warning Tenant or Landlord, as appropriate, of the consequences set forth in this Section 16, will be deemed to establish conclusively that this Lease is in full force and effect
and that the statements set forth in Landlords or Tenants, as applicable, proposed certificate are true, accurate, and correct.

17. TRANSFERS OF LANDLORDS INTEREST.

17.1    Sale, Conveyance and
Assignment. Nothing in this Lease will restrict Landlords right to sell, convey, assign or otherwise deal with the Project, Building or Landlords interest under this Lease.

17.2    Effect of Sale, Conveyance or Assignment. The term Landlord as
used in this Lease, so far as covenants or obligations on the part of the Landlord are concerned, shall be limited to mean and include only the owner or owners, at the time in question, of the fee title to, or a lessees interest in a ground
lease of, the Project. A sale, conveyance or assignment of the Building and/or the Project will automatically release the transferor from liability under this Lease from and after the effective date of the transfer, except for any liability relating
to the period prior to such effective date; and Tenant will look solely to the transferee for performance of Landlords obligations relating to the period after such effective date. This Lease will not be affected by any such sale, conveyance
or assignment and Tenant will attorn to Landlords transferee.

17.3    Subordination and Nondisturbance. Without the necessity of any additional document being executed by Tenant for the purpose of effecting a subordination, and at the
election of Landlord or any mortgagee of a mortgage or a beneficiary of a deed of trust now or hereafter encumbering all or any portion of the Building or Project, or any lessor of any ground or master lease now or hereafter affecting all or any
portion of the Building or Project, this Lease shall be subject and subordinate at all times to such ground or master leases (and such extensions and modifications thereof), and to the lien of such mortgages and deeds of trust (as well as to any
advances made thereunder and to all renewals, replacements, modifications and extensions thereof). As a condition precedent to the effectiveness of any such subordination of this Lease to any future ground or master



32



---

leases or the lien of any future mortgages or deeds of trust, Landlord shall provide to Tenant a commercially reasonable non-disturbance and attornment
agreement in recordable form in favor of Tenant in a form acceptable to Landlord and Tenant executed by such future ground lessor, master lessor, mortgagee or deed of trust beneficiary, as the case may be, which shall provide that Tenants
quiet possession of the Premises shall not be disturbed on account of such subordination to such future lease or lien so long as Tenant is not in default beyond any applicable cure period under any provisions of this Lease. Notwithstanding the
foregoing, Landlord shall have the right to subordinate or cause to be subordinated any or all ground or master leases or the lien of any or all mortgages or deeds of trust to this Lease. In the event that any ground or master lease terminates for
any reason or any mortgage or deed of trust is foreclosed or a conveyance in lieu of foreclosure is made for any reason, at the election of Landlords successor in interest, Tenant shall attorn to and become the tenant of such successor. Upon
attornment this Lease will continue in full force and effect as a direct lease between the Transferee and Tenant, upon all of the same terms, conditions and covenants as stated in this Lease, except the Transferee will not be subject to any set-offs
or claims which Tenant might have against any prior landlord and will not be liable for any act or omission of any prior landlord. Tenant hereby waives its rights under any current or future law which gives or purports to give Tenant any right to
terminate or otherwise adversely affect this Lease and the obligations of Tenant hereunder in the event of any such foreclosure proceeding or sale. Tenant covenants and agrees to execute and deliver to Landlord within fifteen (15) business days
after receipt of written demand by Landlord and in the form reasonably required by Landlord, any additional documents evidencing the priority or subordination of this Lease with respect to any such ground or master lease or the lien of any such
mortgage or deed of trust. Should Tenant fail to sign and return any such documents within said 15 business day period, Tenant shall be in default hereunder without the benefit of any additional notice or cure periods specified in Section 20.1
below. Landlord further agrees that it shall obtain and deliver to Tenant, within thirty (30) days after the execution of this Lease by Landlord and Tenant, the non-disturbance and attornment agreement in recordable form in favor of Tenant in
the form attached hereto as Exhibit Gexecuted by each and every existing mortgagee of a mortgage or beneficiary of a deed of trust encumbering all or any portion of the Building or Project, and any lessor of any ground or
master lease affecting all or any portion of the Building or Project, which shall provide, among other things, that Tenants quiet possession of the Premises shall not be disturbed on account of such mortgage, deed of trust, ground lease or
master lease or the foreclosure (or sale in lieu thereof) or termination of same so long as Tenant is not in default beyond any applicable cure period under any provisions of this Lease. For purposes hereof, the form of non-disturbance and
attornment agreement attached hereto as Exhibit 
G is hereby approved by Tenant and Landlord.

18. RULES AND REGULATIONS. Tenant
agrees to observe and comply with the Rules and Regulations set forth on Exhibit H, the Telecommunications Rules set forth on Exhibit I, and the Parking Rules and Regulations set forth in
Exhibit K(collectively, Project Rules and Regulations) with all reasonable modifications and additions to such Project Rules and Regulations as may be from time to time adopted by Landlord and of which
Tenant is notified in writing. No such modification or addition will contradict or abrogate any right expressly granted to Tenant under this Lease. Landlords enforcement of the Project Rules and Regulations will be uniform and
nondiscriminatory, but Landlord will not be responsible to Tenant for the failure of any person to comply with the Project Rules and Regulations.

19. PARKING.

19.1    Tenants Parking Rights. During the
Term of this Lease (as the same may be extended or renewed), Landlord shall provide to Tenant the number of parking spaces specified in Section 1.1(x) hereof for use by Tenants employees, guests or invitees on a nonexclusive basis in the
common parking areas for the Building within the Project, as designated by Landlord from time to time, located in reasonable proximity to the Building. Landlord shall at all times have the right to establish and modify, on a nondiscriminatory basis,
the nature and extent of the parking areas for the Building and Project (including whether such areas shall be surface, underground and/or other structures) as long as Tenant is provided, on a nondiscriminatory basis, the number of parking spaces
designated in Section 1.1(x). Tenant and its employees shall be provided access to the parking areas for the Project seven (7) days a week and twenty-four (24) hours per day. Throughout the entire Lease



33



---

Term (as the same may be extended and/or renewed) the parking spaces provided to Tenant as specified in Section 1.1(x) shall be free of charge. However,
all costs of operating, maintaining and repairing the parking areas shall be included as Operating Expenses to the extent not otherwise excluded pursuant to Section 1.3(f).

19.2    Parking Rules and Restrictions. The use of the parking areas shall be subject to the
Parking Rules and Regulations attached hereto as Exhibit I and any other reasonable, nondiscriminatory rules and regulations adopted by Landlord and/or Landlords parking operators from time to time, including any system
for controlled ingress and egress. Tenant shall not use more parking spaces than its allotment and shall not use any parking spaces specifically assigned by Landlord to other tenants of the Building or Project. Tenants parking spaces shall be
used only for parking by vehicles no larger than normally sized passenger automobiles or pickup trucks and vans. Tenant shall not permit or allow any vehicles that belong to or are controlled by Tenant or Tenants employees, suppliers,
shippers, customers or invitees to be loaded, unloaded, or parked in areas other than those designated by Landlord for such activities. If Tenant permits or allows any of the prohibited activities described herein, then Landlord shall have the right
without notice, in addition to such other rights and remedies that it may have, to remove or tow away the vehicle involved and charge the cost thereof to Tenant, which cost shall be immediately payable by Tenant upon demand by Landlord.

20. DEFAULT AND REMEDIES

20.1    Tenants Default. The occurrence of any one or more of the following events if uncured before the expiration of the cure periods set forth below, if any,
will be a material default and breach of this Lease by Tenant (Default). Any notice required by the terms of this Lease in connection with any such default will be in lieu of, and not in addition to, any notice required under
Sections 1161, et seq., of the California Code of Civil Procedure so long as such notice otherwise complies with the requirements of Section 1161, et seq. of the California Code of Civil Procedure:

(a) Tenant fails to pay any Rent payment or other sum due under this Lease after the same will be due and payable, and such failure
continues for a period of five days after written notice thereof from Landlord to Tenant, it being understood, however, that Tenant will only be given two (2) such notices and/or cure periods in any twelve (12)-month period or
three (3) such notices and/or cure periods in any twenty-four (24)-month period, and after the second or third (as applicable) such notice given to Tenant by Landlord, any subsequent failure by Tenant to pay amounts when due will
constitute a Default without Landlord providing further notice or opportunity to cure;

(b) Tenant fails to perform or
observe any term, condition, covenant, or obligation required to be performed or observed by it under this Lease for a period of thirty (30) days (or such shorter time provided herein) after notice thereof from Landlord; provided, however, that
if the term, condition, covenant, or obligation to be performed by Tenant is of such nature that the same cannot reasonably be cured within thirty (30) days and if Tenant commences such performance within said 30-day period and thereafter
diligently undertakes to complete the same, then such failure will not be a default hereunder;

(c) A trustee, disbursing
agent, or receiver is appointed to take possession of all or substantially all of Tenants assets in, on or about the Premises or of Tenants interest in this Lease (and Tenant does not regain possession within sixty (60) days after
such appointment); or Tenant makes an assignment for the benefit of creditors; or all or substantially all of Tenants assets in, on or about the Premises or Tenants interest in this Lease are attached or levied upon under execution (and
Tenant does not discharge the same within sixty (60) days thereafter).

(d) A petition in bankruptcy, insolvency, or
for reorganization or arrangement is filed by or against Tenant pursuant to any federal or state statute, and, with respect to any such petition filed against it, Tenant or such guarantor fails to secure a stay or discharge thereof within
sixty (60) days after the filing of the same. In the event that any provision of this Section 20.1(d) is contrary to any applicable Laws, such provision will be of no force or effect.



34



---

(e) Any assignment, subletting, or other transfer for which the prior written consent of
the Landlord has not been obtained where Landlords consent is required.

(f) Discovery of any materially false or
misleading statement knowingly made by Tenant or any guarantor of Tenants obligations under this Lease concerning financial information submitted to Landlord in connection with obtaining this Lease or any other consent or agreement by
Landlord.

(g) Tenants admission in writing of its inability to pay its debts as they mature.

(h) Suspension of Tenants right to conduct its business, caused by the order, judgment, decree, decision, or other act of any court
or governmental agency and Tenants failure to pay Rent as and when due.

(i) Tenants failure to execute,
acknowledge, and deliver to Landlord, within five (5) days after Landlord gives Tenant a second notice that Tenant has failed to deliver any document within the 10-day period specified in Section 17 required to effectuate an attornment, a
subordination, or to make this Lease or any option granted herein prior to the lien of any mortgage, deed of trust, or ground lease, or any estoppel certificate, as the case may be.

20.2    Landlords Remedies. Upon the occurrence of any event of Default, Landlord will have the following
rights and remedies, in addition to those allowed by law or in equity, any one or more of which may be exercised or not exercised without precluding the Landlord from exercising any other remedy provided in this Lease or otherwise allowed by law or
in equity:

(a) Landlord may terminate this Lease and Tenants right to possession of the Premises. If Tenant has
abandoned and vacated the Premises, the mere entry onto the Premises by Landlord in order to perform acts of maintenance, cure defaults, preserve the Premises, or attempt to relet the Premises, or the appointment of a receiver in order to protect
the Landlords interest under this Lease, will not be deemed a termination of Tenants right to possession or a termination of this Lease unless Landlord has notified Tenant in writing that this Lease is terminated. If Landlord terminates
this Lease and Tenants right to possession of the Premises pursuant to this Section 20.2(a), then Landlord may recover from Tenant:

(i) The worth at the time of the award of unpaid Rent, including, without limitation, Excess Expenses, which had been earned at the time of termination; plus

(ii) The worth at the time of the award of the amount by which the unpaid Rent which would have been earned after termination until the
time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(iii) The
worth at the time of the award of the amount by which the unpaid Rent for the balance of the term after the time of the award exceeds the amount of such rental loss that Tenant proves could be reasonably avoided; plus

(iv) Any other amounts necessary to compensate Landlord for all of the detriment proximately caused by Tenants failure to perform
its obligations under this Lease which in the ordinary course of things would be likely to result therefrom, including, without limitation, recovery of Base Rent for any period of free Rent theretofore enjoyed by Tenant (at rates in effect for the
period immediately following such period of free Rent), provided that with regard to any free Rent recoverable by Landlord, such amount shall be reduced by an amount equal to one month of free Base Rent for every full twelve (12) consecutive
months that Tenant has been in occupancy of the Premises (by way of example only, since Tenant is currently entitled to six (6) months and twenty-three (23) days of free Base Rent, if Tenant is in default under this Lease after
twenty-four (24) consecutive months of occupancy, the amount of the free Base Rent recoverable by Landlord would be an amount equal to four (4) months and twenty-three (23) days of Base Rent); any legal expenses, brokers commissions,
or finders fees in connection with reletting the Premises, and the pro rata portion of any leasing commission paid by Landlord in connection with this Lease which is applicable to the portion of the Term, including option periods, which is unexpired
as of the date on which this Lease terminated; the



35



---

costs of repairs, cleanup, refurbishing, removal, and storage or disposal of Tenants personal property, equipment, fixtures, and anything else that
Tenant is required under this Lease to remove but does not remove (including those alterations which Tenant is required to remove pursuant to an election by Landlord, and which Landlord actually removes, whether or not notice to remove will be
delivered to Tenant); and any costs for alterations, additions, and renovations incurred by Landlord in regaining possession of and reletting (or attempting to relet) the Premises.

All computations of the worth at the time of the award of amounts recoverable by Landlord under Sections 20.2(a)(i) and
(ii) hereof will be computed by allowing interest at the maximum lawful rate per annum allowed for commercial transactions as of the date on which the event of default occurred. The worth at the time of the award recoverable
by Landlord under Section 20.2(a)(iii) and the discount rate for purposes of determining any amounts recoverable under Section 20.2(a)(iv), if applicable, will be computed by discounting the amount recoverable by Landlord at the discount
rate of the Federal Reserve Bank of California San Francisco at the time of the award plus one percent (1%).

(b)
Notwithstanding Landlords right to terminate this Lease pursuant to Section 20.2(a), Landlord may, at its option, even though Tenant has breached this Lease and abandoned the Premises, continue this Lease in full force and effect and not
terminate Tenants right to possession, and enforce all of Landlords rights and remedies under this Lease. In such event, Landlord will have the remedy described in California Civil Code Section 1951.4 (Landlord may continue this
Lease in effect after Tenants breach and abandonment and recover Rent as it becomes due, if Tenant has the right to sublet or assign, subject only to reasonable limitations). Further, in such event, Landlord will be entitled to recover from
Tenant all costs of maintenance and preservation of the Premises, and all costs, including attorneys fees and receivers fees, incurred in connection with appointment of and performance by a receiver to protect the Premises and
Landlords interest under this Lease. No reentry or taking possession of the Premises by Landlord pursuant to this Section 20.2(b) will be construed as an election to terminate this Lease unless a written notice (signed by a duly
authorized representative of Landlord) of intention to terminate this Lease is given to Tenant. Landlord may at any time after default by Tenant elect to terminate this Lease pursuant to Section 20.2(a), notwithstanding Landlords prior
continuance of this Lease in effect for any period of time, and upon and after Tenants default under this Lease, Landlord may, but need not, relet the Premises or any part thereof for the account of Tenant to any person, firm, partnership,
corporation, or other business entity for such Rent, for such time, and upon such terms as Landlord, in its sole discretion, will determine. Subject to the provisions of this Lease regarding assignment and subletting in Section 13, Landlord
will not be required to accept any substitute tenant offered by Tenant or to observe any instructions given by Tenant regarding such reletting. Landlord may remove (and repair any damage caused by such removal) and store (or dispose of) any of
Tenants personal property, equipment, fixtures, and anything else Tenant is required (under this Lease at the election of Landlord or otherwise) to remove but does not remove, and Landlord may also make repairs, renovations, alterations,
and/or additions to the Premises to the extent deemed by Landlord necessary or desirable in connection with any attempt to relet the Premises. Tenant will upon demand pay the cost of such repairs, alterations, additions, removal, storage and
renovations, together with any legal expenses, brokers commissions or finders fees and any other expenses incurred by Landlord in connection with its entry upon the Premises and attempt to relet the Premises. If Landlord is able to relet the
Premises for Tenants account during the remaining portion of the Term and the consideration collected by Landlord from any reletting is not sufficient to pay monthly the full amount of Base Rent and Additional Rent payable by Tenant under this
Lease, together with any legal expenses, brokers commissions or finders fees, any cost for repairs, alterations, additions, removal, storage and renovations, and any other cost and expense incurred by Landlord in re-entering the Premises and
reletting the Premises, then Tenant will pay to Landlord the amount of each monthly deficiency upon demand. Any rentals received by Landlord from any such reletting will be applied as follows:

(i) First, to the payment of any costs of reentry and reletting the Premises;

(ii) Second, to the payment of costs of any such alterations, repairs, additions, removal, storage, and renovations to the Premises;



36



---

(iii) Third, to the payment of any other Rent due and unpaid under this Lease; and

(iv) The residue, if any, will be held by Landlord and applied as payment of future Rent as the same may become due and
payable under this Lease.

(c) No act or omission by Landlord or its agents during the Term will be an acceptance of a
surrender of the Premises, and no agreement to accept a surrender of the Premises will be valid, unless made in writing and signed by a duly authorized representative of Landlord. Neither any remedy set forth in this Lease nor pursuit of any
particular remedy will preclude Landlord from any other remedy set forth in this Lease or otherwise available at law or in equity, provided the remedy does not result in a double recovery by Landlord. Landlord will be entitled to a restraining order
or injunction to prevent Tenant from breaching or defaulting under any of its obligations under this Lease other than the payment of Rent or other sums due hereunder.

(d) Neither the termination of this Lease nor the exercise of any remedy under this Lease or otherwise available at law or in equity will
affect the right of Landlord to any right of indemnification set forth in this Lease or otherwise available at law or in equity by reason of Tenants occupancy of the Premises, and all rights to indemnification or other obligations of Tenant
will survive termination of this Lease and termination of Tenants right to possession under this Lease.

20.3    Inducement, Recapture and Effect of Breach. Any agreement by Landlord for free or abated Rent or other charges applicable to the Premises (excluding, however, any abated rent granted under
Sections 4.4(h), 5.3 or 10.3), or for the giving or paying by Landlord to or for Tenant of any cash or other bonus, inducement or consideration for Tenants entering into this Lease, all of which concessions are hereinafter referred to as
Inducement Provisions, and which amounts abated under the Inducement Provisions are collectively referred to herein as the Abated Rent will be deemed conditioned upon Tenants full and faithful performance of all
the terms, covenants and conditions of this Lease to be performed or observed by Tenant during the Term hereof as the same may be extended. Upon the occurrence of a Default, any such Inducement Provision will automatically be deemed deleted from
this Lease and of no further force or effect, as though it had never been a part hereof, and Tenant shall pay to Landlord, as Additional Rent due under this Lease, an amount equal to the amount of the Abated Rent as of the date of Tenants
Default, provided that the amount of Abated Rent recoverable by Landlord shall be reduced by an amount equal to one month of free Base Rent for every full twelve (12) consecutive months that Tenant has been in occupancy of the Premises (by way
of example only, since Tenant is currently entitled to six (6) months and twenty-three (23) days of free Base Rent, if Tenant is in default under this Lease after twenty-four (24) consecutive months of occupancy, the amount of the
free Base Rent recoverable by Landlord would be an amount equal to four (4) months and twenty-three (23) days of Base Rent). The acceptance by Landlord of Rent or the cure of the applicable breach or failure which initiated the operation
of this Section 20.3 will not be deemed a waiver by Landlord of the provisions of this Section 20.3 unless specifically so stated in writing by Landlord at the time of such acceptance.

20.4    Landlords Right to Perform. Except as specifically provided otherwise in this Lease, all covenants and
agreements by Tenant under this Lease shall be performed by Tenant at Tenants sole cost and expense and without any abatement or offset of rent. If Tenant shall fail to pay any sum of money (other than Base Rent) or perform any other act on
its part to be paid or performed hereunder and such failure shall continue for three (3) days with respect to monetary obligations (or ten (10) business days with respect to non-monetary obligations) after Tenants receipt of
written notice thereof from Landlord, and Tenant has not commenced and/or is not diligently pursuing any cure of such failure, Landlord may, without waiving or releasing Tenant from any of Tenants obligations, make such payment or perform such
other act on behalf of Tenant. All sums so paid by Landlord and all necessary incidental costs incurred by Landlord in performing such other acts, together with interest on such sums (calculated at the Interest Rate from the date(s) of expenditure
by Landlord) shall be payable by Tenant to Landlord within five (5) days after Tenants receipt of demand therefor as additional rent. The foregoing rights are in addition to any and all remedies available to Landlord upon Tenants
default as described in Section 20.2.



37



---

20.5    Interest. If any monthly installment of Base Rent or Excess
Expenses, or other amount payable by Tenant or Landlord hereunder is not received by the other party within ten (10) days after the date when due, it shall bear interest at the Interest Rate from the date due until paid. Landlord shall use
commercially reasonable efforts to notify Tenant that such interest has begun to accrue, provided that Landlords failure to provide such notice shall not constitute a waiver of Landlords right to charge or collect such interest.

20.6    Late Charges. Tenant acknowledges that, in addition to interest costs, the late payments by
Tenant to Landlord of any Base Rent or other sums due under this Lease will cause Landlord to incur costs not contemplated by this Lease, the exact amount of such costs being extremely difficult and impractical to fix. Such other costs include,
without limitation, processing, administrative and accounting charges and late charges that may be imposed on Landlord by the terms of any mortgage, deed of trust or related loan documents encumbering the Premises, the Building or Project.
Accordingly, if any monthly installment of Base Rent or Excess Expenses or any other amount payable by Tenant hereunder is not received by Landlord within five (5) days after the same is due, Tenant shall pay to Landlord an additional sum of
four percent (4%) of the overdue amount as a late charge, provided, however, that for the first time (and only the first time) Tenant fails in any twelve (12)-month period to pay any monthly Base Rent or other sum within five (5) days
after the due date, Landlord shall give notice thereof to Tenant (in bold and all capital letters stating that such late charge will be assessed to Tenant) and Tenant shall have three (3) days after receipt of such notice to pay the past due
amount to Landlord prior to application of such late charge. The parties agree that such late charge represents a fair and reasonable estimate of the costs that Landlord will incur by reason of any late payment as hereinabove referred to by Tenant,
and the payment of late charges and interest are distinct and separate in that the payment of interest is to compensate Landlord for the use of Landlords money by Tenant, while the payment of late charges is to compensate Landlord for
Landlords processing, administrative and other costs incurred by Landlord as a result of Tenants delinquent payments. Acceptance of a late charge or interest shall not constitute a waiver of Tenants default with respect to the
overdue amount or prevent Landlord from exercising any of the other rights and remedies available to Landlord under this Lease or at law or in equity now or hereafter in effect.



| | 20.7 | Landlords Default and Tenants Remedies.
| | ---- | -----------------------------------------

(a) It will be a default and breach of this Lease by Landlord if it fails to perform or observe any term, condition, covenant or
obligation required to be performed or observed by it under this Lease for a period of thirty (30) days after written notice thereof from Tenant; provided, however, that, if the term, condition, covenant or obligation to be performed by
Landlord is of such nature that the same cannot reasonably be performed within such thirty (30)-day period, such default will be deemed to have been cured if Landlord commences such performance within said thirty (30)-day period and
thereafter diligently undertakes to complete the same.

(b) In the event of any default on the part of Landlord, Tenant will
give notice by registered or certified mail to any beneficiary of a deed of trust or mortgagee covering the Premises or ground lessor of Landlord whose address shall have been furnished to Tenant, and shall offer such beneficiary, mortgagee or
ground lessor the same opportunity to cure the default as is afforded Landlord pursuant to this Lease.

(c) Tenant will not
have the right based upon a default of Landlord to terminate this Lease or to withhold, offset or abate Rent, Tenants sole recourse for Landlords default being an action for damages against Landlord for diminution in the rental value of
the Premises for the period of Landlords default, which is proximately caused by Landlords default. Tenant will not have the right to terminate this Lease or to withhold, offset or abate the payment of Rent based upon the unreasonable or
arbitrary withholding by Landlord of its consent or approval of any matter requiring Landlords consent or approval, including, but not limited to, any proposed assignment or subletting, Tenants remedies in such instance being limited to
a declaratory relief action, specific performance, injunctive relief or an action of actual damages. Tenant will not in any case be entitled to any consequential or punitive damages based upon any Landlord default or withholding of consent or
approval.



38



---

20.8    Non-waiver of Default. The failure or delay by Landlord to
enforce or exercise at any time any of its rights or remedies or other provisions of this Lease will not be construed to be a waiver thereof, nor affect the validity of any part of this Lease or the right of Landlord thereafter to enforce each and
every such right or remedy or other provision. No waiver by Landlord of any Default or breach of this Lease will be held to be a waiver of any other or subsequent Default or breach. The receipt by Landlord of less than the full Rent due will not be
construed to be other than a payment on account of Rent then due, no statement on Tenants check or any letter accompanying Tenants check be deemed an accord and satisfaction, and Landlord may accept any payment without prejudice to
Landlords right to recover the balance of the Rent due or to pursue any other remedies provided in this Lease or available at law or in equity.

21.    SIGNAGE.

21.1    Signage. Subject to obtaining the
approval of all governmental agencies and authorities with jurisdiction over the Project, Tenant shall have the right to install (a) one (1) sign on the exterior front fascia of the Building as the primary Building identity top sign
displaying Tenants name and/or the name of Tenants Parent, which shall not be located lower than an eye brow sign as shown on Exhibit J attached hereto (Building Signage) and
(b) one monument sign displaying Tenants name and/or the name of Tenants Parent at the entrance of the Building (the Monument Sign), the location of which Building Signage shall be in one of the three locations
set forth in set forth on Exhibit J hereto. In addition, Tenant shall be permitted to install the number of signs on the walls of the elevator lobbies on the Premises as set forth on Exhibit J hereto
(the Lobby Signs). The Building Sign, the Monument Sign and Lobby Signs are collectively referred to herein as the Signage. The Signage and all appurtenant electrical and mechanical installation required in
connection with the Signage shall (i) be installed at Tenants sole cost and expense, (ii) comply with all applicable laws, (iii) be of a size, design, construction, color and materials as set forth on
Exhibit J hereto, (iv) be illuminated (if any illumination is approved or required by Landlord in its reasonable discretion) in a manner acceptable to Landlord in its reasonable discretion, and (v) contain the
standard corporate text of Tenant and/or Tenants Parent, all of which shall be reasonably approved by Landlord. A depiction of Tenants proposed Signage is attached hereto on page 3 of Exhibit Jattached hereto and is
hereby approved by Landlord, provided that all lettering and logos used in such approved Signage shall be dark bronze (i.e., duranotic bronze) and shall be backlit. No other phrases (other than Tenants name or Tenants Parents
name) may be included in any Signage without the prior consent of Landlord. Tenant shall obtain all governmental permits and approvals required in connection with the Signage at Tenants sole cost and expense subject to the application of the
Tenant Improvement Allowance in accordance with Exhibit D. Before beginning installation of the Signage, Tenant shall obtain Landlords written approval of Tenants signage contractor and installer and of all plans
and specifications for the Signage, which approval shall not be unreasonably withheld, conditioned or delayed. Subject to Tenants rights to the Signage, Tenant agrees that notwithstanding that Tenant is paying all costs and expenses relating
to installation of the Signage, Landlord, in Landlords sole, subjective discretion, may allow other tenants of the Building to install signage on the Monument Sign so long as such signage does not interfere with the visibility of the Signage.
On or before the expiration or earlier termination of the Term, Tenant shall, at Tenants sole cost, remove the Signage and repair all damage relating thereto caused by the installation and removal of the Signage, normal wear and tear excepted.
Tenants signage rights under this Section 21.1 are personal to the originally named Tenant under this Lease and in no event shall Tenant assign or otherwise transfer any of its rights with respect to the Signage hereunder; provided,
however, for purposes of this Lease, the originally named Tenant shall include any Permitted Transferee (including Tenants Parent) to whom the Lease has been assigned or transferred in accordance with Section 13 of this Lease.

21.2    Directory Board. Tenant will have the right to include, at Tenants expense, one Building Standard
listing on the Building directory board in the main Building lobby naming Tenant and/or the name of Tenants Parent. Other than the Signage that is permitted in Section 21.1 hereinabove, Tenant will not erect or maintain any temporary or
permanent sign on or about the Premises, the Building or the Project, or visible from the Common Areas or exterior of the Building, without obtaining prior written approval from Landlord, which may be granted or withheld in Landlords sole and
absolute discretion. Any request for approval of a sign will be



39



---

made in such detail as Landlord will request. Landlord will place a Building Standard sign, at Tenants expense, used to identify Tenants business
name and/or the business name of Tenants Parent, at the entrance of the Premises. All signs, whether erected by Landlord or Tenant, will conform to Landlords Building Standard signage and to all Laws. In the event of a violation of the
foregoing by Tenant, Landlord may remove same without any liability, and may charge the expense incurred in such removal to Tenant. Tenant will remove all approved signs which it has erected upon the termination of the Lease and repair all damage
caused by such removal, normal wear and tear excepted.

22.    SECURITY DEPOSITINTENTIONALLY OMITTED

23.    BROKERS. Landlord and Tenant represent and warrant that no broker or agent negotiated or was instrumental in
negotiating or consummating this Lease except the Brokers. Neither party knows of any other real estate broker or agent who is or might be entitled to a commission or compensation in connection with this Lease. Landlord will pay all fees,
commissions or other compensation payable to the Brokers. Tenant and Landlord will indemnify and hold each other harmless from all damages paid or incurred by the other resulting from any claims asserted against either party by any brokers or agents
other than the Brokers claiming through the other party.

24.    LIMITATIONS ON LANDLORDS
LIABILITY. Any liability for damages, breach or nonperformance by Landlord, or arising out of the subject matter of, or the relationship created by, this Lease, will be collectible only out of Landlords interest in the Project and no
personal liability is assumed by, or will at any time be asserted against, Landlord, its parent and affiliated corporations, its and their managers, members, partners, venturers, directors, officers, agents, servants and employees, or any of its or
their successors or assigns; all such liability, if any, being expressly waived and released by Tenant. In no event will Landlord be liable to Tenant or any other person for consequential, special or punitive damages, including, without limitation
lost profits. Landlords review, supervision, commenting on or approval of any aspect of work to be done by or for Tenant are solely for Landlords protection and, except as expressly provided, create no warranties or duties to Tenant or
to third parties.

25.    QUIET ENJOYMENT. Landlord covenants and agrees with Tenant that, upon Tenant
performing all of the covenants and provisions on Tenants part to be observed and performed under this Lease (including payment of rent hereunder), Tenant shall and may peaceably and quietly have, hold and enjoy the Premises in accordance with
and subject to the terms and conditions of this Lease.

26.    TELECOMMUNICATIONS

26.1    Certain Definitions. The following definitions are applicable to this Section 26:

(a) Telecom Equipment means telephone, internet and any other communications equipment, all connections (as
defined below) and any technological evolution or replacement thereof.

(b) Connections means any
wires, cables, fiber optic lines, antennas, switches and other equipment or infrastructure located in the Project, but outside the Premises, that are installed by or on behalf of Tenant for, or related to, the operation of other Telecom Equipment.
All Connections are also Telecom Equipment.

(c) Telecom Provider means a provider of Telecom Equipment
or services using Telecom Equipment. Landlords current Telecom Provider for the Building is Verizon.

(d)
Telecom Services means services provided by a Telecom Provider using Telecom Equipment.

(e)
Wi-Fi is a registered name by the Wi-Fi Alliance. It is short for wireless fidelity, which is a term developed by the Wi-Fi Alliance to describe wireless local area network products that are based on the Institute of Electrical
and Electronics Engineers (IEEE) 802.11 standards.

(f) WiMax is short for worldwide
interoperability for microwave access, and refers to the IEEE 802.16 standard to provide a wireless coverage without a direct line of sight to a base station.



40



---

26.2    New Provider Installations.

(a) Tenant may not utilize the services of a Telecom Provider whose equipment is not then servicing the Project, nor may Tenant require or
request that a Telecom Provider materially expand the Telecom Services or Connections it currently provides or has provided in or to the Project, without first securing the prior written approval of Landlord which approval shall not be unreasonably
withheld, conditioned or delayed.

(b) Tenants Telecom Provider shall, prior to commencing any installation or other
work in the Project, provide proof of insurance reasonably acceptable to Landlord. Landlord will bear no responsibility for (and the Commencement Date will not be affected by) delays in installing Telecom Equipment resulting from failure of
Tenants Telecom Provider to deliver proof of insurance to Landlord prior to the commencement of any installation or other work in the Project; and

(c) Both Tenant and its Telecom Provider(s) will comply with the Telecommunications Rules attached hereto as Exhibit I, together with any other of Landlords requirements regarding use of
the existing Project conduits and pipes or use of contractors.

26.3    Installation and Use of Other
Communications Technologies. Tenant will not utilize any Telecom Equipment (other than usual and customary cellular telephones and wire-based telephone and internet technology or similar telephones), including Wi-Fi and WiMax systems,
antennae and satellite dishes, within the Premises and/or within or on the Project without Landlords prior written consent, which consent shall not be unreasonably withheld, conditioned or delayed.

26.4    No Obligation to Reserve Space. Until Tenants Telecom Provider or Tenant, as the case may be, provides
Landlord with evidence of insurance reasonably acceptable to Landlord, Landlord will have no obligation to reserve space for Tenant for Telecom Equipment anywhere in the Project.

26.5    Plans.Tenant or Tenants Telecom Provider will provide Landlord with plans
and specifications of the installation, modification or removal of the applicable Telecom Equipment, and Landlord will have approved such plans and specifications, before any installation, modification or removal of such Telecom Equipment commences.
Within thirty (30) days after installation, modification or removal of any Telecom Equipment, Tenant will, at its expense, prepare or have prepared and delivered to Landlord reproducible as-built plans and drawings (in form and detail
reasonably satisfactory to Landlord) of the location of all Telecom Equipment serving the Premises and located in the Project. Upon request by Landlord, from time to time, Tenant will promptly deliver copies of the latest as-built plans and drawings
to Landlord (with such copies at Landlords expense if Tenant has otherwise complied with this Section 26.5).

26.6    Limitation of Responsibility. Tenant acknowledges and agrees that all Telecom Equipment will be obtained, installed, maintained, repaired, replaced and removed at the sole expense of Tenant, subject
to Tenants right to apply a portion of the Tenant Improvement Allowance towards the installation of Tenants Telecom Equipment pursuant to the Work Letter Unless Landlord otherwise requests or consents in writing, all of Tenants
Telecom Equipment (other than any Connections) will be and remain solely in Tenants Premises, in accordance with the Telecommunications Rules attached hereto on Exhibit I, together with any other applicable reasonable
Rules and Regulations adopted by Landlord from time to time. Landlord will have no responsibility for the operation, maintenance, repair or replacement of Tenants Telecom Equipment, including, without limitation, Tenants Connections.
Tenant agrees that, to the extent any Telecom Services are interrupted, curtailed or discontinued, Landlord will have no obligation or liability with respect thereto, and it will be the sole obligation of Tenant at its expense to obtain substitute
Telecom Services. No approval by Landlord under this Section 26 will be deemed any kind of warranty or representation by Landlord, including, without limitation, any warranty or representation as to the suitability, competence or financial
strength of any Telecom Provider or the quality or fitness for any particular purpose of any Telecom Equipment or Telecom Services. Landlord does not make, and expressly disclaims, any representation, warranty or endorsement regarding or relating to
any Telecom Provider, Telecom Services or Telecom Equipment.



41



---

26.7    Necessary Service Interruptions. Landlord will have the right
to interrupt Tenants Telecom Services or disable Tenants Telecom Equipment upon the giving of not less than five (5) business days prior written notice to Tenant (except in the event of an emergency, in which case Landlord will
provide Tenant as much advance notice as reasonably possible). Landlord will exercise commercially reasonable efforts to perform any scheduled interruptions in a manner so as to avoid any unreasonable interference with Tenants business
operations.

26.8    Interference. In the event that Telecom Equipment, including, without limitation,
wiring, cabling or satellite and antenna equipment of any type installed by or at the request of Tenant within the Premises, on the roof of the Building or elsewhere within or on the Project causes interference to equipment (including Telecom
Equipment) used by another party, Tenant will be responsible for, and indemnify and defend Landlord against, all liability related to such interference. Tenant will use reasonable efforts, and will cooperate with Landlord and other parties, to
promptly eliminate such interference. In the event that Tenant is unable to eliminate such interference, Tenant will substitute alternative equipment. If such interference persists after such alternative equipment is installed, Tenant will
discontinue the use of its Telecom Equipment as necessary to discontinue such interference, and, at Landlords discretion, remove such Telecom Equipment according to specifications required by Landlord.

26.9    Removal of Telecom Equipment, Wiring and Other Facilities. Prior to the expiration or earlier termination of
the Term, Tenant will remove any and all Telecom Equipment installed in the Premises or elsewhere in the Project by or on behalf of Tenant, including all Connections once the Telecom Equipment is no longer in use, at Tenants sole cost or, if
Landlord so elects, Landlord may perform such removal at Tenants sole cost, with the cost thereof to be paid to Landlord as Additional Rent. Such costs may also include, if Tenant has not complied with Section 26.5, location of such
Telecom Equipment and/or preparation of as-built plans or drawings of the Telecom Equipment serving the Premises and located in the Project. Landlord will have the right, however, upon written notice to Tenant, given prior to the expiration or
earlier termination of the Term, to require Tenant to abandon and leave in place, without additional payment to Tenant or credit against Rent, any and all Connections or selected components thereof, whether located in the Premises or elsewhere in
the Project. The terms and conditions of this Section 26.9 will survive expiration or earlier termination of the Lease.

26.10    No Third Party Beneficiary. Notwithstanding any provision of the preceding paragraphs to the contrary, the provisions of this Lease, including this Section 26, may be enforced solely by Tenant
and Landlord, are not for the benefit of any other party (including any subtenant), and specifically, but without limitation, no Telecom Provider will be deemed a third party beneficiary of this Lease or this Section 26.

27.    MISCELLANEOUS.

27.1    Binding Effect. Each of the provisions of this Lease will extend to, bind or inure to the benefit of, as the case may be, Landlord and Tenant and their respective heirs, successors and assigns,
provided that this clause will not permit any transfer by Tenant contrary to the provisions of Section 13.

27.2    Complete Agreement; Modification. All of the representations and obligations of the parties are contained in this Lease and no modification, waiver or amendment of this Lease or of any of its
conditions or provisions will be binding upon a party unless it is in writing signed by such party.

27.3    Notices. Unless specifically permitted otherwise by the terms of this Lease, all notices required or permitted under this Lease must be in writing and will only be deemed properly given and received
(a) if delivered in person to a party who acknowledges receipt in writing; or (b) if deposited with a private courier or overnight delivery service, if such courier or service confirms delivery; or (c) if deposited in the United
States mails, certified or registered mail with return receipt requested and postage prepaid. All such notices (i) must be transmitted by one of the methods described above to the party to receive the notice at, in the case of notices to
Landlord, both Landlords Managers Address and Landlords General Address, and in the case of notices to



42



---

Tenant, the applicable Tenants Notice Address, or, in either case, at such other address(es) as either party may notify the other of according to this
Section 27.3, and (ii) shall be deemed delivered on the date of actual or constructive receipt by the intended recipient, or on the date such receipt is refused. Any notice to be given by a party under this Lease will be effective if given
by the part or agents or attorneys.

27.4    Delivery for Examination. Submission of the form of the
Lease for examination will not bind Landlord in any manner, and no obligations will arise under this Lease until it is signed by both Landlord and Tenant and delivery is made to each.

27.5    No Air Rights. This Lease does not grant any easements or rights for light, air or view. Any diminution or
blockage of light, air or view by any structure or condition now or later erected will not affect this Lease or impose any liability on Landlord.

27.6    Enforcement Expenses. Each party agrees to pay, upon demand, all of the other partys costs, charges and expenses, including the fees and out-of-pocket expenses of counsel, agents and others
retained incurred in successfully enforcing the other partys obligations under this Lease and any other disputes arising out of this Lease (with successful enforcement being determined by the presiding judge or tribunal). In addition, Landlord
will be entitled to recover from Tenant those costs, charges and expenses related to preparation, delivery and/or service of demand letters, notices of default, notices pursuant to applicable forcible entry and detainer statutes and other similar
correspondence and notices, even if litigation is not commenced or pursued to final judgment after such letters and/or notices are delivered and/or served.

27.7    Relocation of Tenant. Intentionally Omitted.

27.8    Project Name. Tenant will not, without Landlords consent, use Landlords or the Projects name, or any facsimile or reproduction of the Project (or any portion thereof), for any
purpose; except that Tenant may use the Projects name in the address of the business to be conducted by Tenant in the Premises. Landlord reserves the right, upon reasonable prior notice to Tenant, to change the name or address of the Building
and/or the Project.

27.9    Recording; Confidentiality. Tenant will not record this Lease, or a short
form memorandum, without Landlords written consent and any such recording without Landlords written consent will be a Default. Tenant agrees to keep the Lease terms, provisions and conditions confidential and will not disclose them to
any other person without Landlords prior written consent; provided, however, that Tenant may disclose Lease terms, provisions and conditions to Tenants accountants, attorneys, managing employees and others in privity with Tenant, as
reasonably necessary for Tenants business purposes, and as may be required to be disclosed by court order without such prior consent, provided that, upon such disclosure, Tenants accountants, attorneys, managing employees and others in
privity will be bound by the terms of this Section 27.8.

27.10    Captions. The captions of
sections are for convenience only and will not be deemed to limit, construe, affect or alter the meaning of such sections.

27.11    Invoices. All bills or invoices to be given by Landlord to Tenant will be sent to Tenants Invoice Address. Tenant may change Tenants Invoice Address by notice to Landlord given
according Section 27.3.

27.12    Severability. If any provision of this Lease is declared void or
unenforceable by a final judicial or administrative order, this Lease will continue in full force and effect, except that the void or unenforceable provision will be deemed deleted and replaced with a provision as similar in terms to such void or
unenforceable provision as may be possible and be valid and enforceable.

27.13    Jury Trial. LANDLORD
AND TENANT WAIVE TRIAL BY JURY IN ANY ACTION, PROCEEDING OR COUNTERCLAIM BROUGHT BY LANDLORD OR TENANT AGAINST THE OTHER



43



---

WITH RESPECT TO ANY MATTER ARISING OUT OF OR IN CONNECTION WITH THIS LEASE, TENANTS USE AND OCCUPANCY OF THE PREMISES, OR THE RELATIONSHIP OF LANDLORD
AND TENANT.

27.14    Authority to Bind. The individuals signing this Lease on behalf of Landlord and
Tenant represent and warrant that they are empowered and duly authorized to bind Landlord or Tenant, as the case may be, to this Lease according to its terms.

27.15    Only Landlord/Tenant Relationship. Landlord and Tenant agree that neither any provision of this Lease nor any act of the parties will be deemed to create any relationship
between Landlord and Tenant other than the relationship of landlord and tenant.

27.16    Covenants
Independent. The parties intend that this Lease be construed as if the covenants between Landlord and Tenant are independent and not dependent and that the Rent will be payable without offset, reduction or abatement for any cause except as
otherwise specifically provided in this Lease.

27.17    Governing Law. This Lease will be governed by
and construed according to the laws of the State of California.

27.18    Joint and Several Liability. If
two or more parties execute this Lease as Tenant, the liability of each such party to pay all Rent and other amounts due hereunder and to perform all the other covenants of this Lease will be joint and several.

27.19    Counterparts. This Lease may be executed in counterparts, each of which will constitute an original, but all
of which, when taken together, will constitute but one agreement.

27.20    Signing Authority. If Tenant
is a corporation, partnership or limited liability company, each individual executing this Lease on behalf of said entity represents and warrants that he or she is duly authorized to execute and deliver this Lease on behalf of said entity in
accordance with: (a) if Tenant is a corporation, a duly adopted resolution of the Board of Directors of said corporation or in accordance with the by-laws of said corporation, (b) if Tenant is a partnership, the terms of the partnership
agreement, and (c) if Tenant is a limited liability company, the terms of its operating or limited liability company agreement, and that this Lease is binding upon said entity in accordance with its terms. Concurrently with Tenants
execution of this Lease, Tenant will provide to Landlord a copy of: (i) if Tenant is a corporation, such resolution of the board of directors of Tenant authorizing the execution of this Lease on behalf of such corporation, which copy of
resolution will be duly certified by the secretary or an assistant secretary of the corporation to be a true copy of a resolution duly adopted by the board of directors of said corporation and will be in a form reasonably acceptable to Landlord,
(ii) if Tenant is a partnership, a copy of the provisions of the partnership agreement granting the requisite authority to each individual executing this Lease on behalf of said partnership, and (iii) if Tenant is a limited liability
company, a copy of the provisions of its operating or limited liability company agreement granting the requisite authority to each individual executing this Lease on behalf of said limited liability company.

27.21    Approvals under CC&Rs/REA. Landlord and Tenant hereby confirm the following: (i) that Landlord is
currently the Declarant under the CC&Rs/REA, (ii) that notwithstanding the terms of the CC&Rs/REA, the Association has not been established as of the date of this Lease, (iii) that so long as Landlord is the Declarant under the
CC&Rs/REA and no Association has been otherwise established thereunder, all approvals given by Landlord with respect to the initial Leasehold Improvements, the Signage, any Telecom Equipment, Tenants HVAC Units, Tenants Back-Up
Equipment, the Satellite System, the ATM and any other Tenant Changes shall simultaneously constitute the approvals required by Declarant and/or the Association under the CC&Rs/REA, (iv) that upon the giving of such approvals as described
in clause (iii), above, such approvals shall be binding, and so long as such improvements by Tenant have been otherwise installed in accordance with all conditions and requirements set forth in Landlords approval and all applicable Laws,
neither Landlord nor any



44



---

subsequent successor Declarant or Association shall have the right to rescind such approvals, and (v) that upon either the establishment of an
Association under the CC&Rs/REA or the assignment of Landlords rights as Declarant to a successor Declarant under the CC&Rs/REA, any subsequent proposed Tenant Changes or other improvements to the Premises proposed by Tenant shall be
subject to the prior approval of such successor Declarant and/or Association to the extent required under the CC&Rs/REA and to all other applicable provisions under the CC&Rs/REA.

28. OPTION TO RENEW. Subject to Tenant providing Landlord with prior written notice no sooner than twelve (12) months nor later than
nine (9) months prior to the expiration of the Term and Tenant not being in Default (after expiration of all applicable cure periods) of any terms of the Lease as of the delivery of such notice and not being in Default (following written notice
from Landlord) as of the end of the initial term of the Lease, Tenant shall have the option to extend the Lease for all space then under lease by Tenant in the Building, for the period designated in Section 1.1(i) (the Option
Term(s)). The Monthly Base Rent for each Option Term shall be at the then current Fair Market Rental as determined below. As used herein, the Fair Market Rental Rate determination as described in the Section 28
shall mean the monthly amount per rentable square foot, projected for the first day of the Option Term and for each anniversary of the first day of the Option Term thereafter occurring during the Option Term, that has been accepted by landlords
of comparable Class A office buildings located within the Territory (the Comparison Market Area) at arms length for renewal space only for improved space as a renewal Tenant, taking into account tenant improvement
allowances, free rent, leasing commissions, who is paying taxes, insurance and utilities, and rental rates. Within thirty (30) days after receipt of Tenants notice of its election to extend the term of this Lease, Landlord shall provide
Tenant with a statement as to Landlords determination of the Fair Market Rental Rates for the extension period. Unless Tenant objects to such rate within thirty (30) days after Landlord gives Tenant notice of the same, such Fair Market
Rental Rates shall be applicable for the extension period. If Tenant gives Landlord written objection to Landlords determination of the Fair Market Rental Rates for the Premises within such thirty (30)-day period (FMV
Notice), then Landlord and Tenant shall use good faith commercially reasonable efforts to agree upon the determination of the Fair Market Rental Rate for the first year of the extension period and the Fair Market Rental Rates for all
subsequent years during the extension period. If Landlord and Tenant are unable to agree on the determination of the Fair Market Rental Rates within fifteen (15) business days after Landlords receipt of the FMV Notice, the Fair Market
Rental Rates shall be determined by an appraiser mutually selected by both Landlord and Tenant. In the event that Landlord and Tenant cannot mutually agree upon one appraiser within ten (10) business days thereafter, there shall be three
appraisers appointed as follows: (a) each party shall appoint an appraiser and give notice of the appointment to the other party set forth below (respectively, Landlords Appraiser and Tenants
Appraiser), (b) the Landlords Appraiser and Tenants Appraiser shall jointly choose a third appraiser (Third Appraiser) within ten (10) days after appointment of both Landlords Appraiser and
Tenants Appraiser, and (iii) the two appraisals which are closest in value shall then be averaged and the average of the two appraisals shall be the Fair Market Rental Rates for the Premises during the extension period, and the other
appraisal shall not be utilized in such determination. All of the appraisers selected shall be individuals with at least five (5) years commercial appraisal experience in the area in which the Premises are located, shall be members of the
Appraisal Institute (M.A.I.), and in the case of the Third Appraiser, shall not have acted in any capacity for either Landlord or Tenant within five (5) years of his or her selection. Each appraiser shall deliver their determinations of the
Fair Market Rental Rates within ten (10) business days after selection of the Third Appraiser. The cost of the Landlords Appraiser shall be borne by Landlord, the cost of the Tenants Appraiser shall be borne by Tenant, and the cost
of the Third Appraiser shall be shared equally. All other terms and conditions of the initial lease shall remain the same for the extended term of the Lease.

29. RIGHT OF FIRST OFFER. As long as Tenant is not in default under this Lease, if Landlord decides to lease any available First Generation Space (defined below) in the Building to the general
public (ROFO Space), Landlord shall first give written notice to Tenant of the material terms and conditions upon which Landlord is willing to offer to lease the ROFO Space to the general public, which notice shall state in bold
and capital letters the nature of the notice (Landlords Notice). Tenant shall have the right of first offer with regard to such ROFO Space (the Right of First Offer) and shall have ten (10)
business days after Landlords



45



---

Notice is given within which to give written unconditional notice to Landlord that Tenant agrees to lease all (and not less than all) of the ROFO Space on
all the terms and conditions set forth in Landlords Notice (Tenants Notice). If Tenant delivers Tenants Notice to Landlord within the above ten (10) business-day period, the ROFO Space shall become part of
the Premises as of the date on which Tenant shall first have the right to occupy all or any part of that ROFO Space under the terms of Landlords Notice. If Tenant fails to deliver Tenants Notice to Landlord within the above 10
business-day period, Tenants Right of First Offer as to the particular ROFO Space shall automatically terminate and Landlord shall have the right to lease the ROFO Space to any third party (subject, however, to the provisions set forth in
Section 29.1 below). As used herein, First Generation Space means available space in the Building which has not been previously leased or otherwise occupied.

29.1 Any Tenants Notice which contains additional material terms or conditions or which materially differ from or otherwise propose to
materially modify the terms set forth in Landlords Notice shall be deemed a counteroffer by Tenant and shall not be deemed to be an unconditional acceptance of Landlords Notice as provided above, in which case, Landlord shall have the
right, in Landlords sole, subjective discretion, to either accept or reject such counteroffer. If Landlord rejects such counteroffer, or if Tenant fails to deliver Tenants Notice to Landlord within the above five (5)-day period,
Landlord shall have no further obligation to lease such ROFO Space to Tenant and Landlord shall have the right to lease the ROFO Space to any third party on the terms and conditions set forth in Landlords Notice or on any other terms and
conditions that Landlord thereafter negotiates, provided that the ROFO Space may not be offered to any third party on terms that are substantially more favorable than those contained in Landlords Notice delivered to Tenant. As used herein,
substantially more favorable terms means that in a comparison of economic factors between a third party proposal and the terms contained in Landlords Notice, the net effective rental rate (including tenant improvement allowances
and other economic concessions) to a third party would be more than five percent (5%) less than the net effective rate set forth in Landlords Notice. If the net effective rental rate to a third party would be substantially more favorable
than that derived from Landlords Notice, Landlord shall re-offer the ROFO Space to Tenant upon the terms specified in the third party proposal and Tenant shall have the right to lease such ROFO Space in accordance with the same procedures and
time frames as set forth above in this Section 29. If the net effective rental rate to a third party would not be substantially more favorable than that derived from Landlords Notice, Landlord shall have the right to lease the ROFO Space
to such third party or any other third party so long as the terms under the proposed lease are not substantially more favorable than the terms set forth in Landlords Notice.

29.2 If Tenant duly exercises the Right of First Offer as provided above, then Tenant shall enter into an amendment to the Lease
(i) incorporating the ROFO Space into the Lease on the terms and conditions contained in Landlords Notice and (ii) adjusting Tenants Proportionate Share and rent accordingly. All other terms and conditions of the Lease (except
as specified in the immediately preceding sentence) shall remain the same and in full effect. If Tenant fails to duly execute and return the Lease amendment to Landlord within fifteen (15) days after it is delivered to Tenant for signature,
this Right of First Offer as to the ROFO Space and Tenants acceptance of Landlords Notice may, at Landlords sole option, be deemed void, in which case, Tenants exercise of the Right of First Offer as to the ROFO Space shall
be of no further effect, and Landlord shall thereafter be free to unconditionally lease the ROFO Space to one or more third parties as set forth above.

29.3 This Right of First Offer shall not apply to (a) leases or transfers among entities or persons related to Landlord (including, but not limited to, partners if Landlord is a partnership, and
shareholders if Landlord is a corporation), or (b) any proposed sale or purchase of the Building, including, without limitation, a proposed sale-and-leaseback of the Building. The Right of First Offer shall be subject to the preferential rights
of any other tenants in the Building (e.g., options to extend, rights of first refusal/offer and expansion rights). The Right of First Offer shall be exercisable by Tenant on the express condition for Landlords benefit that Tenant
(i) has not been previously in default under this Lease beyond any applicable notice and cure periods, and (ii) shall not be in default under the Lease beyond any applicable notice and cure periods at the time of the exercise of the Right
of First Offer or between such exercise and the execution of the amendment described above incorporating the ROFO Space into the Lease as part of the Premises.



46



---

29.4 This Right of First Offer is personal to Tenant. If Tenant assigns, subleases or otherwise
transfers any of Tenants interest in the Lease or Premises before the permitted exercise of Tenants rights under this Right of First Offer, those rights shall not be transferred to any transferee but shall instead automatically lapse,
and Landlords obligations under this Right of First Offer shall automatically terminate. This Right of First Offer shall automatically expire without notice on the expiration of the original Term or sooner termination of the Lease or upon any
Transfer or sublease by Tenant of all or any part of the Premises.

30. SUPPLEMENTAL HVAC AND BACK-UP EQUIPMENT

30.1    Tenant shall have the right, at Tenants sole cost and expense, to install in such locations within the Building
as shall be designated by Landlord and reasonably approved by Tenant, separate self-contained supplemental HVAC units (Tenants HVAC Units), provided that (i) Tenant shall not install Tenants HVAC Unit until Landlord has
approved the plans and specifications for the work and electrical requirements of Tenants HVAC Unit, provided that if Tenants HVAC Units are installed as part of the Leasehold Improvements the approval of such plans and specifications
shall be processed as part of the approval process for Tenants Final Plans as set forth in the Work Letter, (ii) Tenants HVAC Unit shall be installed in accordance with, and shall comply with at all times, all applicable rules,
regulations, ordinances and laws and Tenant shall obtain all required permits and approvals necessary to install and operate Tenants HVAC Units, (iii) Tenants HVAC Unit shall not adversely affect or interfere with other tenants or
their premises within any portion of the Building or any of the Building Systems, or the design or structural integrity of the Building or any Building warranty, (iv) Tenant shall pay for all costs relating to the installation, operation and
maintenance of Tenants HVAC Units, including, without limitation, all costs of electrical power for Tenants HVAC Units (including, if Landlord so elects in Landlords sole, subjective discretion, the costs of any separate meter
required to measure such electrical usage), (v) in no event shall any portion of the Tenant Improvement Allowance be used to pay for any costs relating to Tenants HVAC Units, (vi) Tenants HVAC Units shall be deemed a Tenant
Change, subject to the terms and conditions of Section 7, (vii) Tenant shall obtain, at Tenants sole cost and expense, any additional insurance reasonably required by Landlord as a result of the installation and operation of
Tenants HVAC Units at the Premises and Building, and (viii) upon the expiration or earlier termination of this Lease, Tenant shall not be required to remove Tenants HVAC Units so long as Tenants HVAC units are in good
operating condition.

30.2    Tenant shall have the right, at Tenants sole cost and expense, to install in
such locations as shall be designated by Landlord and reasonably approved by Tenant, a UPS system and/or a diesel back-up generator to support Tenants computer and communications systems and to provide emergency back-up power for Tenants
operations from the Premises (collectively, Tenants Back-Up Equipment), provided that (i) Tenant shall not install Back-Up Equipment until Landlord has approved the plans and specifications for the work and electrical
requirements of Tenants Back-Up Equipment, (ii) Tenants Back-Up Equipment shall be installed in accordance with, and shall comply with at all times, all applicable rules, regulations, ordinances and laws and Tenant shall obtain all
required permits and approvals necessary to install and operate Tenants Back-Up Equipment, (iii) Tenants Back-Up Equipment shall not adversely affect or interfere with other tenants or their premises within any portion of the
Building or any of the Building Systems, or the design or structural integrity of the Building or any Building warranty, (iv) Tenant shall pay for all costs relating to the installation, operation and maintenance of Tenants Back-Up
Equipment, including, without limitation, all costs of electrical power for Tenants Back-Up Equipment (including, if Landlord so elects in Landlords sole, subjective discretion, the costs of any separate meter required to measure such
electrical usage), (v) in no event shall any portion of the Tenant Improvement Allowance be used to pay for any costs relating to Tenants Back-Up Equipment, (vi) Tenants Back-Up Equipment shall be deemed a Tenant Change,
subject to the terms and conditions of Section 7, (vii) Tenant shall obtain, at Tenants sole cost and expense, any additional insurance reasonably required by Landlord as a result of the installation and operation of Tenants
Back-Up Equipment at the Premises and Building, and (viii) upon the expiration or earlier termination of this Lease, Tenant shall, at Landlords option, remove Tenants Back-Up Equipment and repair all damage caused by such removal at
Tenants sole cost and expense.



47



---

31. SATELLITE EQUIPMENT

31.1    Tenant shall have the right to install and maintain on the roof of the Building small satellite dish/reception antennas and related cabling (collectively, the Satellite
System), at a location to be designated and limited by Landlord in Landlords reasonable discretion. Tenant shall have the right to the reasonable use of the risers in the Building to the extent available and designated by Landlord as
long as there is no adverse affect on the Building Structure or Building Systems or any other tenants premises and subject to restrictions and conditions as may be imposed by Landlord. Prior to such installation, Tenant shall obtain
(i) Landlords written approval, which may be withheld in Landlords reasonable discretion, with respect to the size, weight, design, method of installation, and any screening required by Landlord of all of the above-described
equipment, and (ii) all required governmental and other permits and approvals for the Satellite System from appropriate sources. This installation shall be performed in accordance with all reasonable requirements and criteria imposed by
Landlord in connection therewith. Landlord may direct, but shall not be responsible for the means and methods of installation and no roof penetrations or penetrations between floors shall be permitted without the consent of Landlord, which approval
shall not be unreasonably withheld, conditioned or delayed. Notwithstanding anything to the contrary contained herein, any installation affecting the roof of the Building shall be performed by Landlords roof contractor or such other roof
contractor as may be approved by Landlord in Landlords reasonable discretion, provided that in all events, all work affecting the roof shall be performed in such a manner as to not adversely affect or otherwise impair the existing warranty on
the roof and to the extent such work will adversely affect or otherwise impair the existing roof warranty. Tenant shall first obtain Landlords written consent to such work before commencing the same, which consent may be withheld in
Landlords sole, subjective discretion, provided that Tenant may cause the installation of the Satellite System to be performed as part of the initial Leasehold Improvements pursuant and subject to all of the terms and conditions of the Work
Letter. The Satellite System and all related equipment must be located, installed, and operated so as to not (a) be visible from any location on the ground, or (b) interfere with the operation of any other communications or other equipment
now or hereafter located on the roof, in the Building, or in the vicinity of the Building.

31.2    Tenant will
be solely responsible, at Tenants sole expense, for the installation, maintenance, repair and removal of the Satellite System and related cables, conduits, and other equipment (and for obtaining all required permits and approvals in connection
therewith) and Tenant shall at all times (a) maintain the Satellite System in good condition and repair, and (b) be responsible for the continuous compliance of the Satellite System and its operation and installation with all laws, rules
(including, without limitation, any covenants, conditions, and restrictions affecting the Building), and regulations from time to time applicable. If the weight of the Satellite System and of such other material and equipment which is now or
hereafter located on the roof exceeds the weight bearing capacity of the roof, or may otherwise cause the Building to be in violation of any law or regulation, Tenant shall pay all costs incurred to make all alterations which are needed to reinforce
the roof and/or to otherwise ensure that the Building will be in compliance with all such laws. Tenant shall engage and be responsible for the payment of Landlords roofing consultant (if such engagement is, in Landlords good faith
judgment, necessary to assure the integrity of the Building roof and provided that Landlords roofing contractor and consultant shall not charge Tenant more than they/it would charge Landlord for the same work) and shall implement the
recommendations of the roofing consultant in connection with the installation, replacement or removal of the Satellite Equipment or any portion thereof. Roof access by Tenant for any purpose shall be subject to all rules, regulations, and
restrictions reasonably imposed by Landlord from time to time.

31.3    Tenant acknowledges that Landlord has
made no representation or warranty to Tenant regarding the extent to which transmission or reception by the Satellite System will, or will not be interfered with by helicopters, other equipment installations, other existing or future structures,
antennas, dishes, transmitters, receivers, or other activities on or in the vicinity of the roof, Building, or any other condition or source of interference, or that the condition, design, or weight bearing capacity of the roof is adequate for the
installation, use, or operation of a Satellite System. Tenants installation and use rights under this Section 31 shall only apply with respect to the use of the Satellite System in connection with Tenants operations and a Permitted
Transferees operations in the Premises (as opposed to, e.g., a lease or license of such equipment by Tenant to



48



---

any third party or any assignment, sublease, or other transfer of the Premises [other than to a Permitted Transferee]). Tenant, and not Landlord, shall be
solely responsible for ensuring the satisfactory operation of the Satellite System and that the Satellite System will not interfere in any way with the mechanical, electrical, communication, transmission or other systems of the Building or any other
building located in the vicinity of the Building. Tenant shall indemnify, defend and hold Landlord and any Landlord Party harmless from and against any and all claims, losses, liabilities, actions and damages arising out of Tenants
installation, maintenance and use of the Satellite System, including, without limitation, any claims of interference or injury resulting from Tenants installation, maintenance and use of the Satellite System.

31.4    On or before the expiration or earlier termination of this Lease, Tenant shall remove the Satellite System and related
cables, conduits, and other equipment and repair any damage to the Building caused by such removal. Tenants rights under this Section 31 are personal to Tenant and cannot be otherwise assigned, sublet, or otherwise Transferred (except to
a Permitted Transferee) without the prior written consent of Landlord, which consent may be withheld in Landlords sole, subjective discretion.

32. ATM USAGE. As part of the construction of Leasehold Improvements in accordance with the Work Letter attached as Exhibit D hereto, Tenant shall have the right to install and
maintain one (1) walk-up automated teller machine and night drop machine which is accessible from the exterior of the Premises (the ATM), together with related equipment, accessories and identifying signage (the ATM
Equipment) in the location shown on Exhibit M, on all of the terms, conditions and provisions of this Section 31. Prior to installation of any ATM or ATM Equipment, Tenant shall comply with the provisions of
Exhibit D with respect thereto if the ATM and ATM Equipment is installed as part of the Leasehold Improvements or Tenant shall otherwise comply with Section 7 as if the ATM is a Tenant Change. Tenant shall obtain all
necessary permits and approvals and pay all costs of installing and maintaining the ATM and ATM Equipment. Tenant shall comply with all legal requirements applicable to the installation, use and operation of the ATM and the ATM Equipment. Subject to
Landlords approval not to be unreasonably withheld, conditioned or delayed and signage restrictions imposed by any governmental authority, Tenant shall be permitted to install at the location of the ATM, at Tenants sole cost and expense,
signage identifying Tenant, and automated teller network operated by Tenant, and any shared automatic teller network with which the ATM will be affiliated. Tenant shall be responsible for and shall pay the costs of obtaining all permits or
governmental approvals required for its signs. Tenant shall maintain the ATM, the ATM Equipment and the area in the vicinity thereof in clean and orderly condition. Tenant acknowledges that the Building lobby will not be open to the public other
than during Business Hours. Tenant shall pay Landlord to compensate Landlord for the costs of all utilities dedicated to Tenants operation of the ATM and ATM Equipment (the ATM Utility Charge). The ATM Utility Charge shall
be paid together with the Monthly Base Rent and shall be excluded from Operating Expenses to the extent utilities to the ATM can be separately metered; otherwise, the ATM Utility Charge shall be included as part of Operating Expenses. The amount of
Rentable Square Feet of the Premises and all monetary obligations based on the Rentable Square Feet of the Premises shall be adjusted to reflect the inclusion of the ATM and any related ATM equipment. Tenant shall indemnify, defend and hold Landlord
and the Landlords Parties harmless from any and all claims, demands, causes of action, judgments, costs, expenses, liabilities and damages arising from the installation, operation or use of the ATM or the ATM Equipment, or relating to any act
or occurrence happening in or about the ATM, however the same may be caused except to the extent caused by the gross negligence act or omission or willful misconduct of Landlord or the Landlord Parties. Landlord shall have no responsibility for the
ATM or ATM Equipment, and shall not be liable for any damage to the same no matter how caused except if caused by the gross negligence or willful misconduct of Landlord to any Landlord Parties. Tenant shall pay all real or personal property taxes
assessed or imposed on the ATM or ATM Equipment. Tenant shall cause the insurance policies maintained by Tenant pursuant to Section 9 to cover the ATM and the ATM Equipment and any claims and liabilities arising in connection with the use
thereof and to the extent any additional insurance is required by Landlord as a result of the ATM or ATM Equipment, Tenant shall be responsible for all costs relating to such additional insurance. The ATM and ATM Equipment shall remain the personal
property of Tenant, and upon the expiration or earlier termination of the Term, Tenant shall remove the ATM and ATM Equipment, including signage and other trade fixtures and personal property, and restore the Building and



49



---

Premises (including matching then-existing exterior or interior finishes) to the condition that existed prior to Tenants installation of the ATM,
normal wear and tear excepted. Notwithstanding the foregoing, Tenant may assign its rights under this Section 32 to a Permitted Transferee or other assignee approved by Landlord pursuant to the terms of this Lease so long as such Permitted
Transferee or other approved assignee continues to the use the Premises for the Permitted Use.

(Signatures on Following
Page)



50



---

Landlord and Tenant agree to be bound by the terms and provisions of this Lease, beginning as of the
Effective Date.



|          |  |                                      |  |                                       |  |                                                                                                  |  |                                                                              |  | 
|--------- |  | ------------------------------------ |  | ------------------------------------- |  | ------------------------------------------------------------------------------------------------ |  | ---------------------------------------------------------------------------- |  | 
|TENANT:   |  | FIRST CALIFORNIA BANK,              
|          |  | a California corporation            
|          |  |                                     
|          |  | By:                                  |  |                                      
|          |  | Printed Name:                        |  | C. G. Kum                            
|          |  | Title:                               |  | President and Chief Executive Officer
|          | 
|LANDLORD: |  | WESTLAKE PLAZA CENTER EAST, LLC,    
|          |  | a Colorado limited liability company
|          |  |                                      | 
|          |  |                                      |  | By:                                   |  | Steadfast Business Development, LLC, a Delaware limited liability company, Its: Authorized Agent
|          |  |                                      |  |                                      
|          |  |                                      |  |                                       |  | By:                                                                                              |  | Beacon Bay Holdings, LLC, a Delaware limited liability company, Its: Manager
|          |  |                                      |  |                                       | 
|          |  |                                      |  |                                       |  |                                                                                                  |  | By:                                                                          |  | 
|          |  |                                      |  |                                      
|          |  |                                      |  |                                       |  |                                                                                                  |  |                                                                             
|          |  |                                      |  |                                      
|          |  |                                      |  |                                       |  |                                                                                                  |  | Dinesh Davar, Manager                                                       

Date: November     , 200



51



---

EXHIBIT A

WESTLAKE PARK PLACE

SITE PLAN OF PROJECT

LOGO



52



---

EXHIBIT B

WESTLAKE PARK PLACE

PLAN DELINEATING THE PREMISES

LOGO



53



---

EXHIBIT C

WESTLAKE PARK PLACE

RENTABLE SQUARE FEET AND USABLE SQUARE
FEET

1. The term Rentable Square Feet as used in the Lease shall be deemed to include with respect to the
Premises: (a) the total rentable area of the Premises determined by Landlords architect, including (i) for single tenancy floors, all the area covered by the elevator lobbies, corridors, restrooms, elevator rooms, mechanical rooms,
electrical rooms, telephone closets and janitorial closets on such floors, or (ii) for multiple tenancy floors, a pro-rata portion of all of the area covered by the elevator lobbies, corridors, restrooms, elevator rooms, mechanical rooms,
electrical rooms, telephone closets and janitorial closets on such floor; plus (b) a pro rata portion of (i) the lobby area on the ground floor of the Building, and (ii) the area of the emergency equipment, fire pump equipment,
electrical switching gear, elevator rooms, mechanical rooms, electrical rooms, janitorial closets, telephone equipment and mail delivery facilities serving the Building which are not located on any tenant floor. The Rentable Square Feet shall be
determined by subtracting from the gross measured area of the floor the area of the major vertical penetrations on the same floor, including any elevator shafts, air duct shafts and/or stair shafts. No deduction shall be made for columns and
projections necessary to the Building. Spaces outside the exterior walls, such as balconies, terraces and/or corridors, shall be excluded. The term Rentable Square Feet with respect to the Building shall mean the total rentable
area for all floors in the Building computed in accordance with the provisions of Subparagraph 1(a) above, including the entire lobby and other areas described in Subparagraph 1(b) above. The term Rentable Square Feet
with respect to the Project shall mean the total rentable area for all floors in the Building and the other buildings in the Project, computed in accordance with the provisions of Subparagraph 1(a) above, including the entire lobby and other
areas within such buildings as described in Subparagraph 1(b) above.

2. The term Usable Square Feet as used in
this Lease with respect to the Premises shall be deemed to include the total usable area of the Premises as determined by Landlords Architect, provided that the USF shall not be less than ninety percent (90%) of the RSF.

3. For purposes of establishing the initial Tenants Proportionate Share, Landlords Contribution to Operating Expenses, Base Rent, the amounts
of the Tenant Improvement Allowance, and the number of parking spaces allocated to Tenant as provided in Section 1.1 of the Lease, as well as the amount of the Tenant Improvement Allowance as provided in Exhibit D to the
Lease, the number of Usable Square Feet and Rentable Square Feet of the Premises have been determined to be as set forth in Section 1.1(f) of the Lease, and the number of Rentable Square Feet of the Building shall be determined as set forth
below. Landlords architect shall determine the actual number of Usable and Rentable Square Feet of the Premises, and the Building, based upon the criteria set forth in Paragraph 1 above, and shall provide written confirmation of such
numbers to Tenant within thirty (30) days after delivery of final working drawings for the Building ready for submission to the City/County Building Department. Notwithstanding anything to the contrary herein, Tenant shall have the right to
object to Landlords architects numbers within fifteen (15) days after receipt of written confirmation of such numbers upon a showing that Tenants architects numbers differ from Landlords architects numbers.
In such event, if Landlord and Tenant are unable to reach agreement, each of their architects shall appoint a third architect whose decision shall be binding.



54



---

EXHIBIT D

WESTLAKE PARK PLACE

WORK LETTER

This Work Letter Agreement supplements and is made part of the Office Lease by and between Landlord and Tenant dated November 23, 2007 (the
Lease), and in consideration of the mutual covenants hereinafter contained, Landlord and Tenant agree as follows:

1.
IMPROVEMENTS.

1.1    Delivery of Premises. Landlord will cause to be constructed, at
Landlords sole cost and expense, the Project, the Building and the Premises in a first class condition and working order ready for Tenant to construct Leasehold Improvements (as defined below) as set forth on and in accordance with
Schedule 1 to the Work Letter (collectively Base Building Improvements). The date on which Landlord delivers possession of the Premises to Tenant with the Base Building Improvements complete shall be the Possession
Delivery Date for purposes of this Work Letter Agreement. The Target Possession Delivery Date is January 15, 2008, plus one day for each day Landlords construction of the Base Building Improvements is delayed due to
Tenant Delays or Force Majeure Delays (as defined below). A description of the Base Building Improvements is attached hereto as Schedule 1. Except for the Base Building Improvements, Landlord shall have no obligation to pay or provide
for any improvements, refurbishment or demolition work for the Premises or the Building, except for Landlords contribution of the Tenant Improvement Allowance (as defined below). Tenant shall be solely responsible, at its sole cost and
expense, as part of the Leasehold Improvements (defined below), and subject to Landlords construction of the Base Building Improvements and Landlords contribution of the Tenant Improvement Allowance, for all modifications required to be
made to the existing HVAC systems (including connection to distribution from the Buildings HVAC systems) and electrical systems. Other than with respect to the Base Building Improvements, Tenant shall be solely responsible for bringing the
Premises into compliance with the requirements of the ADA.

1.2.    Tenant Improvements. The tenant
improvements (the Leasehold Improvements) for the Premises, which shall be constructed by Tenant, at Tenants sole cost and expense (except as provided in Paragraph 3.2 below with respect to the Tenant Improvement
Allowance), shall be all improvements to be constructed in and for the Premises and which are permanently affixed to the Premises pursuant to the approved Construction Documents (as defined below), including, without limitation, all carpet, wall
coverings, millwork, doors, counters and partitions; all demising walls; built-in secretarial desks, work stations, and credenzas; all corridors in the Premises; all lunchrooms, kitchens, computer rooms, utility rooms and other special rooms;
Tenants entry door signs; all components and requirements to connect or modify the Buildings HVAC, electrical, telephone, plumbing, life safety and sprinkler systems to service the Premises and prepare the Premises for occupancy (such
as, but not limited to, conduits for lighting changes required to the Premises); and all other tenant improvements for the Premises which Leasehold Improvements shall be constructed using the Building Standard Materials set forth in
Schedule 2 attached hereto or other materials of equal or better quality. Except to the extent set forth in the immediately preceding sentence, the Leasehold Improvements shall not include and the Tenant Improvement Allowance shall not
be used for items such as Tenants furniture, furnishings, equipment, computer systems, work stations, telephones, and/or other personal property which are Tenants personal property or which would normally be considered to be personal
property items belonging to a tenant, whether or not affixed to the Premises. Tenant may install Tenants HVAC Units, Tenants Back-Up Equipment, the Satellite System and the ATM and ATM Equipment and all other non-Leasehold Improvement
items during the same time period as the construction of the Leasehold Improvements and by complying with the same process as provided in connection with the construction of the Leasehold Improvements, including, without limitation, any approval
process for plans and specifications relating to such items.



55



---

2. PLANS AND SPECIFICATIONS.

2.1.    Submission of Tenants Space Plans. Tenant has selected and Landlord hereby approves Ebbe Videriksen as Tenants architect (the Tenants
Architect). Tenant shall also select engineering consultant(s), subject to Landlords approval, which approval shall not be unreasonably withheld, conditioned or delayed (Tenants Engineer) (Tenants
Architect and Tenants Engineer shall be referred to collectively as Tenants Consultants), who, together with Tenants Architect, shall prepare preliminary plans and outline specifications (the
Tenants Space Plans) showing in general the proposed layout and uses to be made of the Premises by Tenant and such other items as are customarily included in preliminary plans and outline specifications, but specifically
including the location and size of restroom facilities, the location and size of kitchen facilities, if any, all walls and partitions (including heights), location and size of Tenant improvements (other than movable furniture, furnishings and
equipment), location, types and sizes of kitchen equipment, if any, location, types and sizes of built-in file cabinets and other facilities not customarily found in offices generally, the location and types of electrical, mechanical and plumbing
lines and connections and other utilities requirements, flooring plans and outline specifications, electrical plans and outline plans and specifications and plumbing plans and outline specifications. The Tenants Space Plans shall be submitted
to Landlord for Landlords written approval (or disapproval and revision), which approval shall not be unreasonably withheld or delayed. When submitting Tenants Space Plans to Landlord, Tenant shall also include a notice, in bold,
underlined and all capital letters, stating that if Landlord fails to approve (or disapprove with revision) Tenants Space Plans within ten (10) business days from the date Landlord receives such notice and Tenants Space Plans,
Landlord shall be deemed to have approved Tenants Space Plans. Landlords failure to disapprove Tenants Space Plans or any portion thereof within the above 10 business-day period shall constitute Landlords approval of the same
provided that the notice (including the language described in the immediately preceding sentence) has been provided to Landlord together with the submittal of Tenants Space Plans. Should Landlord disapprove any portion of Tenants Space
Plans as so submitted by Tenant, Tenant shall submit to Landlord revised Tenant Space Plans incorporating the revisions reasonably required by Landlord within ten (10) business days of Landlords delivery of the disapproved items to
Tenant. If Landlord disapproves of the revised Tenants Space Plans, Landlord shall so notify Tenant within seven (7) business days of Tenants delivery of the revised Tenants Space Plans to Landlord and Tenant shall submit to
Landlord revised Tenant Space Plans to Landlord incorporating the reasonably required revision within seven (7) business days after Landlords disapproval. When submitting any revised Tenants Space Plans to Landlord, Tenant shall
also include a notice, in bold, underlined and all capital letters, stating that if Landlord fails to approve (or disapprove with revision) Tenants Space Plans within seven (7) business days from the date Landlord receives such notice and
Tenants Space Plans, Landlord shall be deemed to have approved Tenants Space Plans. Landlords failure to disapprove any revised Tenant Space Plans within the above 7 business-day period shall constitute Landlords approval of
the same provided that the notice (including the language described in the immediately preceding sentence) has been provided to Landlord together with the submittal of any revised Tenants Space Plans. The foregoing process shall be repeated
until Landlord finally approves all of Tenants Space plans. If Tenant uses the services of Behr Browers Architects (Landlords Architect) to prepare the Tenants Space Plans, the costs of the preparation of the
Tenants Space Plans shall be at Landlords sole cost and expense.

2.2    Tenants Working
Drawings. Following Landlords approval of Tenants Space Plans, Tenants Architect and Tenants Engineer in consultation with Landlords Architect, engineers, construction supervisors, and other consultants
(collectively, the Landlords Consultants) shall prepare fully completed and engineered working drawings and specifications suitable for plan-check review and permitting by local agencies having jurisdiction, for the layout,
improvement and finish of the entire Premises consistent with the design and construction of the Base Building Improvements, including electrical and mechanical drawings, capacity reports, dimensioned partition plans, floor and wall finish plans,
reflected ceiling plans, power, telephone communications and data plans, fire/life safety devices, construction detail sheets including millwork, detail plans showing the location of partitions, light fixtures, electrical outlets, telephone outlets,
sprinklers, doors, equipment specifications (including weight specifications and cooling requirements) and power requirements (including voltage, amps, phase, and special plugs and connections), wall finishes, floor coverings,



56



---

millwork and other Leasehold Improvements required by Tenant (collectively the Working Drawings). The Working Drawings and Construction
Documents (defined below) shall contemplate the use of Building Standard Materials or materials of equal or better quality for the construction of the Leasehold Improvements.

2.3    Landlord Disapproval; Tenant Revisions. The Tenants Working Drawings shall be submitted to Landlord with
copies to Landlords Consultants for Landlords approval which disapproval shall not be unreasonably withheld, conditioned or delayed. Tenants Working Drawings shall be submitted to Landlord together with a notice, in bold,
underlined and all capital letters, stating that if Landlord fails to approve (or disapprove with revision) Tenants Working Drawings within seven (7) business days after Landlords receipt of such notice and Tenants Working
Drawings, Landlord shall be deemed to have approved Tenants Working Drawings. If Landlord disapproves the Tenants Working Drawings, or any portion thereof, it shall promptly, but in no event later than seven (7) business days after
receipt of the Tenants Working Drawings, notify Tenant thereof and of the revisions which Landlord believes are reasonably required in order to obtain Landlords written approval in accordance with the standards set forth above. As
promptly as reasonably possible thereafter, but in no event later than seven (7) business days after receipt of Landlords notice, Tenant shall submit to Landlord plans and specifications incorporating the revisions reasonably required by
Landlord. Said revisions shall be subject to Landlords approval, which shall be subject to the same standards as are set forth above. If Landlord disapproves the revised Tenants Working Drawings, it shall so notify Tenant thereof within
the same time period noted above and of the further revisions Landlord reasonably requires in order to approve Tenants Working Drawings. The foregoing process shall be repeated until Landlord finally approves all of the Tenants Working
Drawings required for the Leasehold Improvements in all of the Premises, so that Landlord and Tenant have an agreed upon set of final plans and specifications. Where Tenant is obligated to approve any document in connection with the Leasehold
Improvements, Tenants failure to disapprove same in the time period allotted herein shall constitute Tenants approval of same. The final Working Drawings, including the final plans and specifications approved by Landlord and Tenant shall
be referred to collectively as the Construction Documents.

2.4.    Changes to Plans.
Tenant shall not be permitted to change the Construction Documents after Landlords approval thereof without first obtaining Landlords consent, which consent shall not be withheld unless the proposed change is materially inconsistent with
the Construction Documents or would violate applicable laws, rules or regulations. Landlord shall notify Tenant of its approval or disapproval (with reasons therefor) within five (5) business days after Landlords receipt of the proposed
changes. Any request for approval of any changes to the Construction Documents shall include a notice, in bold, underlined and all capital letters, stating that if Landlord fails to approve (or disapprove) the proposed changes within
five (5) business days after Landlords receipt of such notice and the proposed changes, Landlord shall be deemed to have approved such changes. Landlords failure to disapprove the proposed changes to the Working Drawings set forth
in such request within the above 5-business day period shall constitute Landlords approval of the same provided that the notice (including the language described in the immediately preceding sentence) has been provided to Landlord together
with the submittal of any requested changes to the Construction Documents. Any such changes and delays in construction of the Leasehold Improvements caused by such changes shall constitute a Tenant Delay (as defined in Paragraph 7 below), shall
be the sole responsibility of Tenant, and shall not delay or extend the Commencement Date (as described in Paragraph 7 below).

2.5.    Landlords Review. Landlords review and approval of the Construction Documents as set forth in Paragraphs 2.2 and 2.3 shall be for its sole purpose and shall not imply
Landlords review of the same, or obligate Landlord to review the same, for quality, design, compliance with building codes or applicable laws or other like matters. Accordingly, notwithstanding that the Construction Documents are reviewed by
Landlord or Landlords Consultants, and notwithstanding any advice or assistance which may be rendered to Tenant by Landlord or Landlords Consultants, Landlord shall have no liability whatsoever in connection therewith and shall not be
responsible for any omissions or errors contained in the Construction Documents. Furthermore, Tenant and Tenants architect shall verify, in the field, the dimensions and conditions as shown on the relevant portions of the plans for the
Building, and Tenant and Tenants architect shall be solely responsible for same, and Landlord shall have no responsibility in connection therewith.



57



---

2.6.    Permits. Tenant shall be responsible for obtaining and
maintaining any necessary governmental permits, including applicable building permits and approvals, relating to the Leasehold Improvements and Construction Drawings. Tenant agrees that neither Landlord nor Landlords Consultants shall be
responsible for obtaining any permits, temporary certificate of occupancy or certificate of occupancy for the Premises with regard to the Leasehold Improvements and Construction Drawings and that Tenant shall be solely responsible for obtaining such
permits and certificates; provided, however, that Landlord and Landlords Consultants shall cooperate (without any additional cost or expense to Tenant) with Tenant in executing permit applications and performing other ministerial acts
reasonably necessary to enable Tenant to obtain any such permits or certificates of occupancy.

3. TENANT IMPROVEMENT COSTS/ALLOWANCE.

3.1.    Tenant Improvement Costs. As used herein, the term Tenant Improvement
Costs shall mean all of the costs to design, construct and install the Leasehold Improvements, including without limitation, the costs of the following:

3.1.1. all design work required to construct the Leasehold Improvements to the Premises, including without limitation, space planning,
architectural and engineering design and documents, interior design and documents, graphics design and documents, and the fees of Tenants Consultants, Landlords Consultants and any special consultants which may be necessary, except for
the fees and costs of Landlords Architect in preparing the Tenants Space Plan in the event Tenant uses Landlords Architect for same which fees and costs shall be paid solely by Landlord;

3.1.2. all permits, connection fees, plan checks, inspections and license fees related to the construction and installation of Leasehold
Improvements required in and for the Premises; and

3.1.3. all other costs related to the construction and installation of
the Leasehold Improvements, including, without limitation, the costs of:

(a) Construction, installation, modification,
delivery and distribution to the Premises of all HVAC, electrical, plumbing, life safety (other than strobe lights), and sprinkler systems;

(b) The cost of installing suite and directory signage in accordance with Landlords criteria; and

(c) The cost of labor, materials, supplies, contractors overhead, fees and general conditions;

Tenant Improvement
Costs shall not include the costs of Tenants systems or equipment, except for Telephone Cable which actually constitute or would normally constitute Tenants personal property; such personal property-type items, together with
Tenants furniture, equipment and other personal property (collectively, FF&E), are not and shall not be considered part of the Leasehold Improvements. The FF&E shall be paid for by Tenant at its sole cost and expense
and not out of the Tenant Improvement Allowance.

3.2.    Tenant Improvement Allowance. Tenant shall be
solely responsible for payment on a timely, lien-free basis the entire Tenant Improvement Costs; provided, however, that Landlord shall contribute for the benefit of Tenant an allowance of Forty-Five and 00/100 Dollars ($45.00) per USF of the
Premises (the Tenant Improvement Allowance) to pay the Leasehold Improvement Costs. The Tenant Improvement Allowance shall be disbursed in the manner described in Paragraph 3.4, below, and shall be used solely to assist
Tenant in the payment of the Tenant Improvement Costs. All items of Leasehold Improvements, whether or not the cost thereof is covered by the Tenant Improvement Allowance, shall become the property of Landlord upon their installation in the Premises
and shall remain on the Premises at all times during and upon expiration of the Term.

3.3.    Excess
Costs. Tenant shall be responsible for all Tenant Improvement Costs and Tenant shall pay all such costs directly to the contractor or other party requesting payment as and when due, provided that nothing contained in this sentence shall be
construed to waive Tenants right to receive the Tenant Improvement Allowance.



58



---

3.4.    Disbursement of
Tenant Improvement Allowance. The Tenant Improvement Allowance shall be paid upon completion of the Leasehold Improvements on the basis set forth below. Tenant shall submit to Landlord, from time-to-time during construction of the Leasehold
Improvements (but not more than once per month) and upon completion of the Leasehold Improvements, a written request for disbursement of all or a portion of the Tenant Improvement Allowance (Request). The Request shall include a
copy of all bills and invoices (Bills and Invoices) which Tenant has or is required to pay in connection with the amount then being requested for reimbursement and a certification from Tenants construction representative and
the Selected Contractor (as defined below) that the amount set forth in the Request has been paid or is due and owing, together with a copy of all conditional and final lien releases and waivers, as applicable for a project in progress or a
completed project, and if a completed project, a temporary certificate of occupancy, and all other information reasonably requested by Landlord relating to the amount then being reimbursed. Disbursement of the Tenant Improvement Allowance shall be
conditioned upon the following: (a) Landlords receipt of such Bills and Invoices, information, and lien releases and waivers, (b) upon completion of the Tenant Improvements, the determination that the Tenant Improvements are
Substantially Complete, and (c) the determination that no substandard work exists which adversely affects the Building systems or the structural or exterior appearance of the Building or any other tenants use of its leased premises in the
Building. Provided Tenant delivers such Bills and Invoices, information, and lien releases and waivers to Landlord on or before the 15thday of a
calendar month and otherwise satisfies the conditions set forth in clauses (a) through (c), above, Landlord shall issue a check equal to the sum of the Bills and Invoices but not to exceed the remaining amount of the Tenant Improvement
Allowance on or before the 15thday of the immediately following calendar month. Landlord shall have the option to issue all checks issued in
connection with this Work Letter Agreement as payable to Tenant.

4. CONSTRUCTION OF TENANT IMPROVEMENTS.

4.1.    Selected Contractor. Landlord hereby approves Al Lowe as Tenants general contractor (the Selected
Contractor). Tenant shall enter into a contract with the Selected Contractor containing such provisions as are agreeable to Tenant in its discretion; provided, however, that the contract (the Construction Contract) shall
provide the warranties called for by Section 4.4 hereof. Notwithstanding the foregoing, Tenant or the Selected Contractor shall be required to subcontract (i) any mechanical work relating to the Leasehold Improvements with Landlords
mechanical contractor (Air Control), and (ii) any roofing work relating to the Leasehold Improvements with a roofing contractor designated by Landlord; provided said roofing contractor charges Tenant not more than it would charge Landlord for
similar work. Tenant shall enter into a construction contract with the Selected Contractor and Tenant shall be solely responsible for the performance of the work of the Leasehold Improvements to be performed by the Selected Contractor and all
Tenants Agents (defined below) performing services for the Tenant and/or the Selected Contractor in accordance with the provisions of this Work Letter Agreement. Tenant shall deliver a copy of the Construction Contract to Landlord within
three (3) business days after it is signed by Tenant.

4.2.    Tenants Agents. All
subcontractors, laborers, material suppliers used by Tenant for contracts over $50,000.00 must be approved in writing by Landlord, which approval shall not be unreasonably withheld, conditioned or delayed (such subcontractors, laborers, materialmen,
and suppliers, and the Selected Contractor are referred to collectively herein as Tenants Agents.

4.3.    Landlords General Conditions for Tenants Agents and Leasehold Improvement Work. Tenants and Tenants Agents construction of the Leasehold Improvements shall comply with
the following: (i) the Leasehold Improvements shall be constructed in strict accordance with the approved Construction Documents using Building Standard Materials or other materials of equal or better quality, (ii) Tenant and Tenants
Agents shall not unreasonably interfere with, obstruct, or delay, any other work in the Building; (iii) Tenants Agents shall submit schedules of all work relating to the Leasehold Improvements to Landlord and the Selected Contractor and
the Selected Contractor and Landlord shall, within three (3) business days of receipt thereof, inform Tenants Agents of any reasonable changes which are necessary thereto, and Tenants Agents shall adhere to such reasonably corrected
schedule; and (iv) Tenant shall abide by all reasonable rules made by



59



---

Landlords Building contractor or Landlords Building manager with respect to the use of freight, loading dock and service elevators, storage of
materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Work Letter Agreement, including, without limitation, the construction of the Leasehold Improvements; provided, however, that such
rules shall not be discriminatorily applied against Tenant nor unreasonably delay Tenants construction of the Leasehold Improvements. Notwithstanding the foregoing, neither Tenant nor the Selected Contractor shall be charged for, and Landlord
shall provide for Tenants Architect, Tenants Engineer, designers, contractors and subcontractors working on the Leasehold Improvements, continuous access to and service to the Project, Building and Premises including, without limitation,
parking, electricity, water, elevators, (including freight elevators), access to loading docks, toilets, temporary HVAC and other Building facilities and services, prior to and during the construction of the Leasehold Improvements and during
Tenants move into the Premises.

4.4.    Requirements of Tenants Agents. Selected Contractor
shall guarantee to Tenant and for the benefit of Landlord that the portion of the Leasehold Improvements for which it is responsible shall be free from any defects in workmanship and materials for a period of not less than one (1) year from the
date of Substantial Completion thereof. Selected Contractor shall be responsible for the replacement or repair, without additional charge, of all work done or furnished in accordance with the Construction Contract that shall become defective within
one (1) year after the later to occur of (i) Substantial Completion of the work performed by such contractor or subcontractors and (ii) the Commencement Date. The correction of such work shall include, without additional charge, all
additional expenses and damages incurred in connection with such removal or replacement of all or any part of the Leasehold Improvements, the Building and/or the Project that may be damaged or disturbed thereby. All such warranties or guarantees as
to materials or workmanship of or with respect to the Leasehold Improvements shall be contained in the construction contract or subcontract and shall be written such that such guarantees or warranties shall inure to the benefit of both Landlord and
Tenant, as their respective interests may appear, and can be directly enforced by either. Tenant covenants to give to Landlord any assignment or other assurances which may be reasonably necessary to effect such right of direct enforcement.

4.5.    Governmental Compliance. Tenants Agents shall construct the Leaseholds Improvements
in compliance with the following: (i) all state, federal, city or quasi governmental laws, codes, ordinances and regulations, as each may apply according to the rulings of the controlling public official, agent or other person;
(ii) applicable standards of the American Insurance Association (formerly, the National Board of Fire Underwriters) and the National Electrical Code; and (iii) where applicable, building material manufacturers specifications.

4.6.    Supervision/Inspection by Landlord. Landlord shall have the right to inspect and review
construction of the Leasehold Improvements at all times; provided, however, that Landlords failure to inspect or supervise construction of the Leasehold Improvements shall in no event constitute a waiver of any of Landlords rights
hereunder nor shall Landlords inspection of the Leasehold Improvements constitute Landlords approval of the same. Should Landlord, in good faith, reasonably disapprove any portion of the Leasehold Improvements, Landlord shall notify
Tenant in writing of such disapproval and shall specify in reasonable detail the items disapproved; provided, however, that Landlord shall not disapprove any portion of the Leasehold Improvements which have been constructed in accordance with the
approved Construction Documents. Any defects or deviations in, and/or disapproval by Landlord of, the Leasehold Improvements shall be rectified by Tenant at no expense to Landlord, provided, however, that in the event Landlord determines that a
defect or deviation exists or disapproves of any matter in connection with any portion of the Leasehold Improvements and such defect, deviation or matter might adversely affect the mechanical, electrical, plumbing, heating, ventilating and air
conditioning or life-safety systems of the Building, the structure or exterior appearance of the Building or any other tenants use of its leased premises, Landlord may, take such action as Landlord deems reasonably necessary to correct any
such defect, deviation and/or matter, including, without limitation, causing the cessation of performance of the construction of the Leasehold Improvements until such time as the defect, deviation and/or matter is corrected. Should Landlords
action with regard to any defect or deviation be unreasonable, not in good faith, or not supported by the facts, Landlords action shall constitute a Landlord Delay (subject, however, to the provisions of Section 7.2).



60



---

4.7.    Notice of Completion; Copy As-Built Plans. Within
ten (10) days after Substantial Completion of construction of the Leasehold Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the County of Ventura in accordance with Paragraph 3093 of
the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same on behalf of Tenant as Tenants agent for
such purpose, at Tenants sole cost and expense. At the conclusion of construction, (i) Tenant shall cause Tenants Architect and the Selected Contractor (a) to update the approved Construction Documents as necessary to reflect
all changes made to the approved Construction Documents during the course of construction, (b) to certify to the best of their knowledge that the record-set of as-built drawings are true and correct, which certification shall
survive the expiration or termination of this Lease, and (c) to deliver to Landlord two (2) sets of sepias and one (1) electronic copy of the as-built drawings on CD within ninety (90) days following issuance of a temporary
certificate of occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the Leasehold Improvements in the Premises.

4.8.    Coordination by Tenants Agent with Landlord. Upon Tenants delivery of the Construction Contract to
Landlord under Paragraph 4.1 of this Work Letter Agreement, Tenant shall furnish Landlord with a schedule setting forth the projected date of the Substantial Completion of the Leasehold Improvements and choosing the critical time deadlines for
each phase, item or trade relating to the construction of the Leasehold Improvements. Each party shall cooperate with the other to coordinate Tenants construction of the Leasehold Improvements such that Tenant can complete the Leasehold
Improvements in a timely fashion. In this regard, Tenants Consultants, the Selected Contractor and Landlords construction representative shall meet together on a weekly basis (or such other basis as mutually agreed to by the parties)
during the construction of the Leasehold Improvements.

4.9.    Construction of Leasehold Improvements.
Following Landlords approval of the Construction Documents, Tenants selection of the Selected Contractor, Tenants obtaining of all applicable permits and governmental approvals, and Tenants compliance with the other
provisions of this Paragraph, Tenant shall cause the Leasehold Improvements to be diligently and expeditiously constructed by the Selected Contractor, lien free and asbestos free, in accordance with the approved Construction Documents and such
permits and approvals. If in the good faith, reasonable judgment of Landlord the presence of Tenants Agents and the work that is being performed by Tenants Agents unreasonably and materially disrupts tenant improvement or other work
being performed by Landlord or others in the Building or Project, or cause labor disputes, Landlord shall have the right, on twenty-four (24) hours written notice to Tenant, to order any or all of Tenants work to cease for as long as
reasonably required by Landlord, and such action by Landlord shall not constitute a Landlord Delay notwithstanding any provisions of Paragraph 7.2 below to the contrary unless Landlords action is unreasonable, not in good faith, or not
supported by the facts in which case such action shall be deemed a Landlord Delay hereunder.

4.10    Landlord
Coordination Fee. Landlord shall not charge Tenant nor shall Tenant or Tenants Agents be required to pay any construction coordination or oversite fees to Landlord in connection with the design, construction or installation of the
Leasehold Improvements.

5. INSURANCE REQUIREMENTS.

5.1.    General Coverages. All of Tenants Agents shall carry workers compensation insurance covering all of their respective employees, and shall also carry public
liability insurance, including property damage, all with limits, in form and with companies as are required to be carried by Tenant as set forth in Section 9 of the Lease, and the policies therefor shall insure Landlord, Landlords
managing agent and Tenant as their interests may appear, as well as the Selected Contractor and subcontractors.

5.2.    Special Coverages. Tenant shall carry Builders All Risk insurance in an amount approved by Landlord covering the construction of the Leasehold Improvements and such other insurance
as Landlord may require. Such insurance shall be in amounts and shall include such extended coverage endorsements as may be reasonably required by Landlord.



61



---

5.3.    General Terms. Certificates for all insurance carried pursuant
to this Paragraph 5.3 shall be delivered to Landlord before the commencement of construction of the Leasehold Improvements and before the Selected Contractors equipment is moved onto the site. All such policies of insurance must contain a
provision that the company writing the policy will give Landlord not less than fourteen (14) days prior written notice of any cancellation or lapse of the effective date or any reduction in the amounts of such insurance. In the event that the
Leasehold Improvements are damaged by any cause during the course of the construction thereof other than the negligence or willful misconduct of Landlord, Landlord Parties, or Landlord Consultants, Tenant shall cause the Selected Contractor or
subcontractor, as applicable, to immediately repair the same at Tenants sole cost and expense if not otherwise covered by the Construction Contract, it being understood that either Tenant or the Selected Contractor shall be solely responsible
for such repair (and all costs relating thereto) and Landlord shall have no responsibility or liability in connection therewith. Selected Contractor shall maintain all of the foregoing insurance coverage in force until the Leasehold Improvements are
fully completed and accepted by Landlord, except for any Products and Completed Operation Coverage insurance required by Landlord, which is to be maintained for ten (10) years following Substantial Completion of the work and acceptance by
Landlord and Tenant. All insurance, except Workers Compensation, maintained by Selected Contractor shall preclude subrogation claims by the insurer against anyone insured thereunder. Such insurance shall provide that it is primary insurance as
respects the owner and that any other insurance maintained by owner is excess and noncontributing with the insurance required hereunder. The requirements for the foregoing insurance shall not derogate from the provisions for indemnification of
Landlord by Tenant under Paragraph 6 of this Work Letter Agreement or of Tenant by Landlord under the terms of this Lease.

6.
INDEMNITY. Tenants indemnities of Landlord as set forth in the Lease shall also apply with respect to any and all costs, losses, damages, injuries and liabilities related in any way to any act or omission of Tenant or
Tenants Agents, or anyone directly or indirectly employed by any of them, or in connection with Tenants non-payment of any amount arising out of the Leasehold Improvements required to be paid by Tenant. Such indemnities by Tenant shall
also apply with respect to any and all costs, losses, damages, injuries and liabilities related to Landlords performance of any ministerial acts reasonably necessary, (i) to permit Tenant to complete the Leasehold Improvements, and
(ii) to enable Tenant to obtain any building permit, temporary certificate of occupancy or certificate of occupancy for the Premises, except to the extent that such costs, losses, damages, injuries or liabilities are caused by the gross
negligence or willful misconduct of Landlord, or any Landlord Party or any Landlord Consultant.

7. LEASE COMMENCEMENT DATE: LANDLORD DELAYS.

7.1.    Commencement Date. The Commencement Date shall be the date that is the earlier of
(i) one hundred twenty (120) days following the Possession Delivery Date plus one day for each day the design, construction or installation of the Leasehold Improvements is delayed due to Landlord Delays or Force Majeure Delays or
(ii) the date Tenant commences business from the Premises.

7.2.    Landlord Delays. For purposes of
this Work Letter Agreement, Landlord Delays shall mean any actual delay in the design, construction or installation of the Leasehold Improvements which is caused by any of the following:

7.2.1.    Approvals. Landlords failure to give approvals or disapprovals of the Tenants
Space Plans, Tenants Working Drawings or Construction Documents or any modification thereof within the time periods specified in this Work Letter Agreement; or

7.2.2.    Access. Landlords failure to provide Tenant or Tenants contractors reasonable
access to the Premises specified in this Work Letter Agreement or as otherwise reasonably required for the design, construction or installation of the Leasehold Improvements by Tenant; or

7.2.3.    Interference. Any other act or failure to act of Landlord, Landlord Parties or Landlord
Consultants which Landlord is not entitled to do under the provisions of the Lease or this Work Letter



62



---

Agreement, or otherwise, and which actually interferes with and delays the Substantial Completion of the Leasehold Improvements, including Landlords
failure to make payments to Tenant of any portion of the Tenant Improvement Allowance as required by this Work Letter Agreement.

Notwithstanding the foregoing provisions of this Paragraph 7.2 to the contrary, no Landlord Delay shall be deemed to occur unless and until Tenant provides written notice to Landlord, in compliance with the Lease, claiming that such
delay has occurred and specifying in detail the action or inaction on the part of Landlord which is the basis for such claim. If such action or inaction is not cured by Landlord within two (2) business days after receipt of such notice
(Count Day), then the Landlord Delay as set forth in such notice shall be deemed to have occurred commencing as of the Count Day and continuing for the number of days the action or inaction claimed by Tenant in such notice remains
uncured and actually and directly causes a delay in the design, construction or installation of the Leasehold Improvements beyond such date.

7.3.    Tenant Delays. For purposed of this Work Letter Agreement, Tenant Delays shall mean any actual delay in Tenants Substantial Completion of the Leasehold Improvements which is
caused by (a) Tenants failure to perform any obligation in accordance with and by the date specified in this Work Letter Agreement or (b) Tenants changes in the Construction Documents after Landlord approves the Construction
Documents. A delay in Substantial Completion of the Leasehold Improvements as a result of Tenant Delays shall not cause the Commencement Date to be delayed. No Tenant Delay shall be deemed to occur unless and until Landlord provides written notice
to Tenant, in compliance with the Lease, claiming that such delay has occurred and specifying in detail the action or inaction on the part of Tenant which is the basis for such claim. If such action or inaction is not cured by Tenant within
two (2) business days after receipt of such notice (Count Day), then the Tenant Delay as set forth in such notice shall be deemed to have occurred commencing as of the Count Day and continuing for the number of days the
action or inaction claimed by Landlord in such notice remains uncured and actually and directly causes a delay in the design, construction or installation of the Leasehold Improvements beyond such date.

7.4.    Substantial Completion. For purposes hereof, Substantial Completion of the Leasehold
Improvements shall occur (i) upon the completion of construction of the Leasehold Improvements pursuant to the approved Construction Documents, with the exception of any punchlist items and any Tenant fixtures, furniture, equipment or other
personal property, and (ii) a temporary certificate of occupancy has been issued for the Premises by the appropriate governmental authorities.

7.5    Force Majeure Delays. If either Landlord or Tenant is delayed, hindered in or prevented from the performance of any act required under this Lease by reason of strikes, lock-outs, labor troubles,
inability to procure standard materials, failure of power, restrictive governmental laws, regulations or orders, riots, civil unrest or insurrection, war, fire, earthquake, flood or other natural disaster, unusual and unforeseeable delay which
results from an interruption of any public utilities (e.g., electricity, gas, water, telephone) or other unusual and unforeseeable delay not within the reasonable control of the party delayed in performing work or doing acts required under the
provisions of this Lease (a Force Majeure Delay), then, except as otherwise specifically provided in this Lease, performance of such act will be excused for the period of the delay and the period for the performance of any such
act will be extended for a period equivalent to the period of such delay.

7.6    Right to Terminate.
Tenant shall have the right to terminate this Lease by giving written notice thereof to Landlord if, but only if (a) Tenant has obtained all necessary governmental approvals and permits to complete the Leasehold Improvements and is otherwise
ready to immediately commence the Leasehold Improvements, (b) the Construction Documents have been finalized and approved by Landlord, (c) Tenant has entered into the Construction Contract with the Selected Contractor and (d) subject
to day-for-day extensions due to Landlord Force Majeure Delays or Tenant Delays, the Possession Delivery Date does not occur on or before January 15, 2008. Such termination shall occur thirty (30) days after Landlords receipt of
notice from Tenant that it has elected to terminate this Lease unless Landlord causes the Base Building Improvements to be completed, within such thirty (30)-day period.



63



---

8. MISCELLANEOUS.

8.1.    Clean-Up Expenses. Landlord, at its sole cost and expense, shall clean the Premises within one (1) day prior to the Possession Delivery Date and within seven (7)
days after the Substantial Completion of the Leasehold Improvements. The cleaning referenced in the first sentence of this Paragraph 8.1 shall leave the Premises in a broom clean condition. The costs of the cleaning provided by Landlord
pursuant to this Section shall not be included in Operating Expenses for the Building. The HVAC systems for the Premises shall run continuously for twelve (12) hours per day, seven (7) days per week during the seven (7) day
period following Substantial Completion of the Leasehold Improvements to flush out and purge new finish odors, all at Landlords sole cost and expense.

8.2.    Tenants Representative. Tenant has designated Al Lowe as its sole representative with respect to the matters set forth in the Work Letter Agreement, who, until further
notice to the Landlord, shall have full authority and responsibility to act on behalf of the Tenant as required in this Work Letter Agreement.

8.3.    Landlords Representative. Landlord has designated Lance Emery as its sole representative with respect to the matters set forth in this Work Letter Agreement, who, until further notice to
Tenant, shall have full authority and responsibility to act on behalf of the Landlord as required in this Work Letter Agreement.

8.4    Tenants Lease Default. Notwithstanding any provision to the contrary contained in this Lease, if an event of default by Tenant as described in the Lease, or a default by Tenant under this Work
Letter Agreement, has occurred at any time on or before Substantial Completion of the Leasehold Improvements, and such default remains uncured after the applicable notice and cure periods under the Lease, then (a) in addition to all other
rights and remedies granted to Landlord pursuant to the Lease, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance, and/or Landlord may cause the Selected Contractor to cease the construction
of the Tenant Improvements (in which case Tenant shall be responsible for any delay in the Substantial Completion of the Tenant Improvements caused by such work stoppage and such delay shall not be a Landlord Delay), and (b) all other
obligations of Landlord under the terms of this Work Letter Agreement shall be forgiven until such time as such default is cured pursuant to the terms of the Lease.



64



---

First California Bank

SCHEDULE 1

to

EXHIBIT D

BASE BUILDING DEFINITION

The Building and Base Building components shall be constructed in compliance with all applicable laws and building codes for normal office use, including
Title 24 and ADA. The Building and Project common areas shall be landscaped in a manner consistent and similar to the Project. The Building, including all structural wall, floor and roof support systems, shall be constructed with sound structural
integrity, including insulation, and all Building systems shall be maintained in good operating order. Landlord, at its expense, shall deliver the Building and Premises to Tenant in a shell condition which shall include the following:

Typical Common Areas



| |  |  | Building lobbies to be completed with all flooring finishes, wall finishes, ceiling treatments and lighting.
| | - |  | ------------------------------------------------------------------------------------------------------------



| |  |  | Mens and womens public restrooms to have hot and cold water and completed with toilets, urinals, sinks, countertops, including necessary hardware,
lighting and all wall, flooring and ceiling finishes, and required exhaust.
| | - |  | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Chilled drinking fountain at the Core.
| | - |  | --------------------------------------



| |  |  | All finishes for elevator cabs.
| | - |  | -------------------------------



| |  |  | Elevator lobby in unfinished shell condition. Finishes to be designed and installed by Tenant and in accordance with Schedule 2 to
Exhibit C.
| | - |  | -----------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Ventilation shafts and painted fire stairwells. Shafts and stairwells to be drywall enclosed per code requirements.
| | - |  | -------------------------------------------------------------------------------------------------------------------



| |  |  | Electrical and telephone/communication rooms with main feeder ducts and service from the electrical and telephone/communication providers.
| | - |  | ------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | (4) 4 non-dedicated telephone and telecommunications conduits with pull strings to be provided to the
3rdFloor. MPOE on 1stfloor. (LL verifying
whether 1 or more of the 4 inch conduit may be dedicated to 1stCalifornia Bank).
| | - |  | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------

Useable Office Space Premises



| |  |  | Main electrical feeder lines and transformers to be connected to 2 points on each floor, ready for Tenants electrical distribution.
| | - |  | ------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Electrical Load provide at 277/480 3 phase, 4 wire.
| | - |  | ---------------------------------------------------



| |  |  | Landlord to provide approximately 10 watts per rentable square foot of tenant area.
| | - |  | -----------------------------------------------------------------------------------



| |  |  | Landlord to provide approximately 7 watts at 208v/120v per rentable square foot of tenant area and 168 breakers.
| | - |  | ----------------------------------------------------------------------------------------------------------------



| |  |  | Power for Lighting shall be provided at 277/480v: 1.5 watts per rentable square foot with the number of branch circuits based on a load of 300 watts per
20 ampere, 277 volt branch circuit.
| | - |  | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Power for general office HVAC: as required by building system to support stated electrical demand load( unresolved being evaluated by both parties).
| | - |  | ----------------------------------------------------------------------------------------------------------------------------------------------------



65



---

| |  |  | HVAC main vertical ducting and piping stubbed into premises, ready to receive Tenants distribution ductwork.
| | - |  | -------------------------------------------------------------------------------------------------------------



| |  |  | Building shall include 800 cfm of exhaust capacity for premises (TTs rep verifying exhaust requirements) TBD.
| | - |  | --------------------------------------------------------------------------------------------------------------



| |  |  | Base Building mechanical systems designed to industry acoustical standards for Class A office; noise level not to exceed NC- 25.
| | - |  | --------------------------------------------------------------------------------------------------------------------------------



| |  |  | Landlord shall furnish outside air sufficient to comply with ASHRAE requirements for Tenants after hours occupied areas.
| | - |  | -------------------------------------------------------------------------------------------------------------------------



| |  |  | In the event that Tenant elects to use the ceiling plenum space as return air plenum, Landlord shall provide evidence that the structure immediately above
Tenants ceiling is fire rated in accordance with the applicable codes.
| | - |  | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Outside air delivered to the premises shall be filtered using a minimum 30% efficient filters; outside air requirements consistent with ASHRAE Standard 62-1989 and
Title 24.
| | - |  | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Indoor winter and summer conditions: 75 degrees +/- 2 degrees; outdoor summer and winter conditions in accordance with ASHRAE publications; summer design to .5%
column; winter design to .2 column; population density 1/100 USF; minimum of 1.25 watts per RSF dissipating heat for lighting and equipment (not including computer and copy rooms or base building equipment rooms) TTs rep reviewing.
| | - |  | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | LL contractor reviewing TT perimeter heating requirement.
| | - |  | ---------------------------------------------------------



| |  |  | Emergency Power  Landlord shall provide emergency power to operate all shell essential building services per codes
including (1stCal list not required by code, LLs representative to include those items that are required by code).
| | - |  | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Main fire sprinkler system and piping installed throughout the floor with sprinkler heads installed in the plenum.
| | - |  | ------------------------------------------------------------------------------------------------------------------



| |  |  | Concrete floors to be level and prepped to receive Tenants carpeting and hard surface flooring.
| | - |  | ------------------------------------------------------------------------------------------------



| |  |  | Finished ceiling height to accommodate a minimum 8 feet 9 inches, except at the soffit at the upper floors around the perimeter of the Building.
| | - |  | ------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | A minimum of 3 points of connection in Premises for domestic water in the Building.
| | - |  | -----------------------------------------------------------------------------------



| |  |  | A minimum of 3 points of connection per floor for plumbing waste lines in the Building.
| | - |  | ---------------------------------------------------------------------------------------



| |  |  | Floor structural load designed to 50psf in office areas and 100psf in exiting areas.
| | - |  | ------------------------------------------------------------------------------------



| |  |  | Fire Alarm pull stations and fire extinguishers provided for shell; Emergency egress signage at each stairwell entrance.
| | - |  | ------------------------------------------------------------------------------------------------------------------------



| |  |  | Fire Alarm Control Panel to be provided for Building Shell. Landlord shall evaluate Panels capacity to support Tenants devices upon Tenants
delivery of TI fire alarm scope detail. Tenant shall provide for monitoring and testing of the devices to be installed in the Premises.
| | - |  | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------

Exterior Glass



| |  |  | Exterior glass shall be energy efficient, tinted and free of cracks, scratches and marring.
| | - |  | -------------------------------------------------------------------------------------------



| |  |  | The glass and glass framing system shall be designed, constructed and sealed to protect against moisture penetration, and reduce transmission of exterior noise from
the adjacent freeway.
| | - |  | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| |  |  | Interior window mullions to be painted or finished.
| | - |  | ---------------------------------------------------



| |  |  | Window height to be approximately 8 inches above floor to finished ceiling height of 9 feet except at the upper floors around the perimeter of the
Building.
| | - |  | ------------------------------------------------------------------------------------------------------------------------------------------------------------



66



---

Surface and Structured Parking Areas



| |  |  | Parking areas to be paved and all stalls to be striped.
| | - |  | -------------------------------------------------------

Security System  Tenant shall have the right to install a security system, including card key access and card readers for the Premises.



67



---

SCHEDULE 2

to

EXHIBIT D

BUILDING STANDARD IMPROVEMENTS

1.
Partitions



| | a. | Demising Partitions:
| | -- | --------------------

3 5/8 x
25 Ga. metal studs at 24 on center with 5/8 Type X gypsum board each side to finished ceiling, (9-0 AFF); R-7 insulation within wall cavity. Seismic bracing per City of Thousand Oaks Building Department.
Gypsum board taped smooth to receive paint. Pertinent metal casing beads where applicable.



| | b. | Interior Partitions:
| | -- | --------------------

3 5/8 X
25 Ga. metal studs at 24 on center with 5/8 Type X gypsum board each side to the finished ceiling 9-0). Seismic bracing per City of Thousand Oaks Building Department. Gypsum board taped smooth to receive
paint. Pertinent metal casing where applicable.



| | c. | Tunnel Corridor Partitions:
| | -- | ---------------------------

3 5/8X
25 GA metal studs at 24 on center with 5/8 Type X gypsum board each side. Connect to gypsum board corridor ceiling for tunnel corridor. Seismic bracing per City of Thousand Oaks building department. Gypsum board taped
smooth to receive finish.

2. Door Assembly



| | a. | Tenant Single 20 Min. Entry Door:
| | -- | ---------------------------------



| | (i) | Door
| | --- | ----

3-0 X 8-10 X 1 3/4, Western Oregon Door Co. Quarter
Sliced (type of wood, stain and finish to be specified by Tenant and reasonably approved by Landlord); 20 minute label. Pre-sand and stain to match building standard finish.



| | (ii) | Frame
| | ---- | -----

3-0 X 9-0
Wilson Partitions Clear Anodized Aluminum with snap on casing, color: Clear Anodized Aluminum; 20 minute label.



| | (iii) | Hardware (Polished Chrome)
| | ----- | --------------------------



|                |  |       |  |             |  |           |  |           |  |        
|--------------- |  | ----- |  | ----------- |  | --------- |  | --------- |  | -------
|Lockset         |  | 1 set |  | L9453TX-17A |  |           |  | 629       |  | Schlage
|Hinges          |  | 3 pr. |  | 5BB1        |  | 41/2x41/2 |  | Stainless |  | Ives   
|Closer          |  | 1 ea. |  | PA4041      |  |           |  | Sat Chr   |  | LCN    
|Floor Stop      |  | 1 ea. |  | 1214        |  |           |  | Sat Chr   |  | Trimco 
|DustProofStrike |  | 1 ea. |  | DP2         |  |           |  | Sat Chr   |  | Ives   



| | b. | Tenant Pair 20 Min. Entry Doors:
| | -- | --------------------------------



| | (i) | Door
| | --- | ----

3-0 X 8-10 X 1 3/4, Western Oregon Door Co. Quarter
Sliced (type of wood, stain and finish to be specified by Tenant and reasonably approved by Landlord); 20 minute label. Pre-sand and stain to match building standard finish.



| | (ii) | Frame
| | ---- | -----

3-0 X 9-0
Wilson Partitions Clear Anodized Aluminum with snap on casing, color: Clear Anodized Aluminum; 20 minute label.



68



---

| | (iii) | Hardware (Polished Chrome)
| | ----- | --------------------------



|                |  |       |  |             |  |           |  |           |  |        
|--------------- |  | ----- |  | ----------- |  | --------- |  | --------- |  | -------
|Lockset         |  | 1 set |  | L9453TX-17A |  |           |  | 629       |  | Schlage
|Hinges          |  | 3 pr. |  | 5BB1        |  | 41/2x41/2 |  | Stainless |  | Ives   
|Closer          |  | 1 ea. |  | PA4041      |  |           |  | Sat Chr   |  | LCN    
|Floor Stop      |  | 1 ea. |  | 1214        |  |           |  | Sat Chr   |  | Trimco 
|Coordinator     |  | 1 ea. |  | COR52xFL20  |  |           |  | Sat Chr   |  | Ives   
|Astragal        |  | 1 ea. |  | 355CS       |  |           |  | SatAlum   |  | Pemko  
|DustProofStrike |  | 1 ea. |  | DP2         |  |           |  | Sat Chr   |  | Ives   
|Flush Bolt      |  | 1 ea. |  | FB41P       |  |           |  | Sat Chr   |  | Ives   



| | c. | Tenant Single Interior Door (Non-locking):
| | -- | ------------------------------------------



| | (i) | Door
| | --- | ----

3-0 X 8-10 X 1 3/4, Western Oregon Door Co. Quarter
Sliced (type of wood, stain and finish to be specified by Tenant and reasonably approved by Landlord); 20 minute label. Pre-sand and stain to match building standard finish.



| | (ii) | Frame
| | ---- | -----

3-0 X 9-0
Wilson Partitions Clear Anodized Aluminum with snap on casing, color: Clear Anodized Aluminum; 20 minute label.



| | (iii) | Hardware (Polished Chrome)
| | ----- | --------------------------



|                |  |       |  |           |  |           |  |           |  |        
|--------------- |  | ----- |  | --------- |  | --------- |  | --------- |  | -------
|Latchset        |  | 1 set |  | L9010-17A |  |           |  | 620       |  | Schlage
|Hinges          |  | 3 pr. |  | 5BB1      |  | 41/2x41/2 |  | Stainless |  | Ives   
|Floor Stop      |  | 1 ea. |  | 1214      |  |           |  | Sat Chr   |  | Trimco 
|DustProofStrike |  | 1 ea. |  | DP2       |  |           |  | Sat Chr   |  | Ives   



| | d. | Tenant Pair Interior Doors (Non-locking):
| | -- | -----------------------------------------



| | (i) | Door
| | --- | ----

3-0 X 8-10 X 1 3/4, Western Oregon Door Co. Quarter
Sliced (type of wood, stain and finish to be specified by Tenant and reasonably approved by Landlord); 20 minute label. Pre-sand and stain to match building standard finish.



| | (ii) | Frame
| | ---- | -----

3-0 X 9-0
Wilson Partitions Clear Anodized Aluminum with snap on casing, color: Clear Anodized Aluminum; 20 minute label.



| | (iii) | Hardware (Polished Chrome)
| | ----- | --------------------------



|                |  |       |  |            |  |           |  |           |  |        
|--------------- |  | ----- |  | ---------- |  | --------- |  | --------- |  | -------
|Latchset        |  | 1 set |  | L9010-17A  |  |           |  | 629       |  | Schlage
|Hinges          |  | 3 pr. |  | 5BB1       |  | 41/2x41/2 |  | Stainless |  | Ives   
|Closer          |  | 1 ea. |  | PA4041     |  |           |  | Sat Chr   |  | LCN    
|Floor Stop      |  | 1 ea. |  | 1214       |  |           |  | Sat Chr   |  | Trimco 
|Coordinator     |  | 1 ea. |  | COR52xFL20 |  |           |  | Sat Chr   |  | Ives   
|Astragal        |  | 1 ea. |  | 355CS      |  |           |  | SatAlum   |  | Pemko  
|DustProofStrike |  | 1 ea. |  | DP2        |  |           |  | Sat Chr   |  | Ives   
|Flush Bolt      |  | 1 ea. |  | FB41P      |  |           |  | Sat Chr   |  | Ives   



| | e. | Tenant Single Locking Interior Door Assembly:
| | -- | ---------------------------------------------



| | (i) | Door
| | --- | ----

3-0 X 8-10 X 1 3/4, Western Oregon Door Co. Quarter
Sliced (type of wood, stain and finish to be specified by Tenant and reasonably approved by Landlord); 20 minute label. Pre-sand and stain to match building standard finish.



69



---

| | (ii) | Frame
| | ---- | -----

3-0 X 9-0
Wilson Partitions Clear Anodized Aluminum with snap on casing, color: Clear Anodized Aluminum; 20 minute label.



| | (iii) | Hardware (Polished Chrome)
| | ----- | --------------------------



|                |  |       |  |           |  |           |  |           |  |        
|--------------- |  | ----- |  | --------- |  | --------- |  | --------- |  | -------
|Latchset        |  | 1 set |  | L9050-17A |  |           |  | 629       |  | Schlage
|Hinges          |  | 3 pr. |  | 5BB1      |  | 41/2x41/2 |  | Stainless |  | Ives   
|Floor Stop      |  | 1 ea. |  | 1214      |  |           |  | Sat Chr   |  | Trimco 
|DustProofStrike |  | 1 ea. |  | DP2       |  |           |  | Sat Chr   |  | Ives   



| | f. | Tenant Pair Locking Interior Doors:
| | -- | -----------------------------------



| | (i) | Door
| | --- | ----

3-0 X 8-10 X 1 3/4, Western Oregon Door Co. Quarter
Sliced (type of wood, stain and finish to be specified by Tenant and reasonably approved by Landlord); 20 minute label. Pre-sand and stain to match building standard finish.



| | (ii) | Frame
| | ---- | -----

3-0 X 9-0
Wilson Partitions Clear Anodized Aluminum with snap on casing, color: Clear Anodized Aluminum; 20 minute label.



| | (iii) | Hardware (Polished Chrome)
| | ----- | --------------------------



|           |  |       |  |           |  |           |  |           |  |        
|---------- |  | ----- |  | --------- |  | --------- |  | --------- |  | -------
|Latchset   |  | 1 set |  | L9050-17A |  |           |  | 629       |  | Schlage
|Hinges     |  | 3 pr. |  | 5BB1      |  | 41/2x41/2 |  | Stainless |  | Ives   
|Closer     |  | 1 ea. |  | PA4041    |  |           |  | Sat Chr   |  | LCN    
|Floor Stop |  | 1 ea. |  | 1214      |  |           |  | Sat Chr   |  | Trimco 



|                |  |       |  |            |  |         |  |      
|--------------- |  | ----- |  | ---------- |  | ------- |  | -----
|Coordinator     |  | 1 ea. |  | COR52xFL20 |  | Sat Chr |  | Ives 
|Astragal        |  | 1 ea. |  | 355CS      |  | SatAlum |  | Pemko
|DustProofStrike |  | 1 ea. |  | DP2        |  | Sat Chr |  | Ives 
|Flush Bolt      |  | 1 ea. |  | FB41P      |  | Sat Chr |  | Ives 

3. Ceiling System



| | a. | Ceiling Tile:
| | -- | -------------

Armstrong 3251 Optima Square
Tegular, 24 x 24 x 5/8 tile, color  white. Score ceiling tile where ceiling tile meets walls for flush installation.



| | b. | Ceiling Grid:
| | -- | -------------

Armstrong Silhouete XL,
24 x 24, 9/16 bolt system 1/8 reveal, color - white. Suspension system shall comply with ASTM C635 specifications. Compression struts to conform to Title 24.

4. Fluorescent Light Fixtures

Lithonia 2-0 x 4-0 fluorescent fixture
2 M3NGB33218LD277, 18 cell, 3 parabolic louvered lenses. All fixtures include three (3) 34-watt miser lamps, 4000 kelvin temperature. Provide earthquake clips as required. Connect night lights to building emergency panel. Provide
approximately one (1) fixture per 80 (eighty) square feet of office area.

or

Lithonia 2-0 x 4-0 fluorescent fixture 2 AV3CF40GEB1015, Avante (Indirect Light). All fixtures include
three (3) 34-watt miser lamps, 4000 kelvin temperature. Provide earthquake clips as required. Connect night lights to building emergency.



70



---

Lithonia 2-0 x 2-0 fluorescent fixture, 2 M3NGB2U3169LD277 9 cell, 3
parabolic louvered lenses. All fixtures include three (3) 34-watt miser lamps, 4000 kelvin temperature. Provide earthquake clips as required. Connect night lights to emergency panel.

5. Fire Sprinkler

Reliable, semi-recessed
chrome heads with electrostatically painted escutcheons to match ceiling tile. Install centerline of ceiling tiles. No heads are to be installed within 2-0 of the nearest wall.

6. Light Switch Assembly



| | a. | Wall mounted: Novitas #01-211 motion sensor in accordance with Title 24 requirements. One (1) sensor at each office. Color: White
| | -- | ---------------------------------------------------------------------------------------------------------------------------------



| | b. | One-way ceiling: Novitas #01-100 ceiling mounted motion sensor in accordance with Title 24 requirements. Override switch for reception areas and conference rooms. Color:
white.
| | -- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | c. | Two-way ceiling: Novitas #01-110 ceiling mounted motion sensor in accordance with Title 24 requirements. Override switch for reception areas and conference rooms.
| | -- | ------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | d. | Override switch: Novitas #01-210, super switch mini. Color: white.
| | -- | ------------------------------------------------------------------

7. Electrical Duplex Outlets

Leviton or equal 110v, 3-prong, 2-pole grounded duplex receptacle. White color. Mounted
vertically. Outlet height to be 17 AFF to center line of outlet.

8. Telephone Wall Outlets

Single gang box in wall mounted vertically with 3/4 metal conduit to terminate 6 above ceiling line. Install box vertically 17 above finished floor to center line of outlet: color as requested by Tenant.
All Teflon wire and cover plates to be provided by Tenants installer. One (1) outlet for each office or work station. Color: white.

9. HVAC



| | a. | Furnish and install standard VAV air distribution ductwork. Roof equipment and ductwork within interior core walls existing. All in accordance with Title 24 Requirements.
| | -- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | b. | Furnish and install variable air volume boxed, approximately one (1) per 1,000 square feet of floor area.
| | -- | ---------------------------------------------------------------------------------------------------------



| | c. | Furnish and install air registers and return air grill, approximately one (1) per 250 square feet of floor area.
| | -- | ----------------------------------------------------------------------------------------------------------------



| | d. | Design and engineer system by licensed mechanical engineer in accordance with all Title 24 Requirements.
| | -- | --------------------------------------------------------------------------------------------------------

10. Exit Signs

Lithonia, Edge-lit series
LRP1GC 120/277 ELN Number of faces may vary between 1 and 2 as well as arrow direction.

11. Fire Extinguishers



| | a. | Amerex model A500 (5lb., ABC 2A 10 C)
| | -- | -------------------------------------



| | b. | Amerex model A441 (10lb., ABC 4A 60 C)
| | -- | --------------------------------------



| | c. | Cabinet: Semi-recessed Potter Roemer #7023 fire cabinet
| | -- | -------------------------------------------------------



71



---

12. Paint (Tenant Interior)

Coats to cover  Frazee Lo-Glo interior latex paint. Color as requested by Tenant. Two (2) coats to cover. Tenant allowed one (1) accent color and one (1) base color. All walls to be painted.

13. Carpet

Designweave
Tempest Classic 32 ounce solid color cut pile carpet over 3/8 Nova Pad. Color: to be selected by Tenant.

14. Vinyl Base

Burke 21/2 (straight at carpet, coved at vct) vinyl topset base. Color as requested by Tenant.

15. Vinyl Flooring

Armstrong Excelon Imperial texture 12x12x1/8 vinyl tile in standard
colors. Color as requested by Tenant.

16. Window Coverings

Exterior Windows: Vertical blinds, Newport Shading Systems, 949-673-0766, Vinyl coated polyester yarns woven to produce an openness of five percent (5%). Vane width 3-1/2 with head rail and sill channels
#HA-8000 series, color: #NF180-white. Blinds at all exterior windows.

17. Elevator Lobby.

Elevator Lobby finishes to be consistent with Westlake Park Place lobby themes defined by the Project Architect. Finishes Specifications to be determined.
Awaiting Contractor submittals.

18. Building Permit

One (1) City of Westlake Village Building Permit for the value of the building standard work within the Tenants usable square footage.

19. Architectural Fees



| | a. | Preparation of building standard space studies.
| | -- | -----------------------------------------------



| | b. | Preparation of building standard Final Plans for above work.
| | -- | ------------------------------------------------------------

20.
Over Standard Materials

[To be provided, if applicable]



72



---

EXHIBIT E

WESTLAKE PARK PLACE

NOTICE OF LEASE TERM DATES



|    |  |      
|--- |  | -----
|To: |  | Date:



| | Re: | Office Lease dated                     ,
20        between Tenant, and WESTLAKE PLAZA CENTER EAST, LLC, Landlord, concerning Suite             (Premises) located at
            Townsgate Road, Westlake Village, California
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------

Gentlemen:

In accordance with the above-referenced Lease, we wish to advise and/or confirm as follows:

1. That the Premises have been accepted by Tenant as being substantially complete in accordance with the Lease, and as except as to latent defects, that
there is no deficiency in construction.

2. That Tenant has accepted and is in possession of the Premises, and acknowledges that under the
provisions of the Lease, the Term of the Lease is for             (            ) years, with
                    , and commenced upon the Commencement Date of
                    , 20        and is currently scheduled to expire on
                    , 20        , subject to earlier termination as provided in the Lease.

3. That in accordance with the Lease, rental payment has commenced (or shall commence) on
                    , 20        .

4. If the Commencement Date of the Lease is other than the first day of the month, the first billing will contain a pro rata adjustment and the billing
thereafter, with the exception of the final billing, shall be for the full amount of the monthly installment as provided for in the Lease.

5. Rent is due and payable in advance on the first day of each and every month during the Term of the Lease. Your rent checks should be made payable to
                    at                     .

6. The exact number of Rentable Square Feet within the Premises is
                    (            ) square feet. The exact number of Usable
Square Feet within the Premises is                    
(            ) square feet.

7. Tenants Proportionate Share as
adjusted based upon the exact number of Rentable Square Feet within the Premises, consists of two (2) separate percentages:

(a)             percent (            %) which is Tenants Proportionate Share of the Building; and

(b)             percent (            %), which is Tenants Proportionate Share of the Project.

AGREED AND ACCEPTED



|           |  |                                                                       |  |                                                                            |  |                                                                 |  |        
|---------- |  | --------------------------------------------------------------------- |  | -------------------------------------------------------------------------- |  | --------------------------------------------------------------- |  | -------
|LANDLORD |  | WESTLAKE PLAZA CENTER EAST, LLC, a
Colorado limited liability company
|           |  |                                                                      
|           |  | By:                                                                   |  | Steadfast Business Development, LLC, a Delaware limited liability company,
|           |  |                                                                       |  | Its:                                                                       |  | Authorized Agent                                               
|           |  |                                                                       | 
|           |  |                                                                       |  | By:                                                                        |  | Beacon Bay Holdings, LLC, a Delaware
limited liability company,
|           |  |                                                                       |  |                                                                            |  | Its:                                                            |  | Manager



73



---

| |  |  |  |  |  |                       |  | 
| |  |  |  |  |  | --------------------- |  | 
| |  |  |  | 
| |  |  |  |  |  | By:                   |  | 
| |  |  |  |  |  | Dinesh Davar, Manager

|         |  |      |  |  |  |  |  | 
|-------- |  | ---- |  |  |  |  |  | 
|         | 
|TENANT |  | ,   
|         |  |     
|         |  | a    |  | 
|         |  |      | 
|         |  | By:  |  |  |  | 
|         |  |      | 
|         |  | Its: |  |  |  | 
|         |  |      | 
|         |  | By:  |  |  |  | 
|         |  |      | 
|         |  | Its: |  |  |  | 

SAMPLE ONLY [NOT FOR EXECUTION]



74



---

EXHIBIT F

WESTLAKE PARK PLACE

FORM ESTOPPEL CERTIFICATE

Tenant Estoppel Certificate



|To: | Bank of America, N.A.
|--- | ---------------------

| | 700 Louisiana Street, 5thFloor
| | ------------------------------

| | Houston, Texas 77002
| | --------------------

| | Attention: Joyce Eng
| | --------------------

|   |  | 
|-- |  | 
|Re |  | 
|   |  | 

1.    The undersigned (Tenant), as the tenant of approximately
            square feet of space (the Premises) under that certain Lease dated
                    ,             (the Lease) made with
                    , Landlord, covering space in Landlords building (the Building) in
                    County,             , known as
                    , hereby certifies as follows:

(a) That attached hereto as Exhibit A is a true, correct and complete copy of the Lease, together with all amendments thereto;

(b) That the Lease is in full force and effect and has not been modified, supplemented or amended in any way except as set forth in
Exhibit A. The interest of Tenant in the Lease has not been assigned or encumbered;

(c) That the
Lease, as amended as indicated in Exhibit A, represents the entire agreement between the parties as to said leasing, and that there are no other agreements, written or oral, which affect the occupancy of the Premises by
Tenant;

(d) That all insurance required of Tenant under the Lease has been provided by Tenant and all premiums have been
paid;

(e) That the commencement date of the term of the Lease was

(f) That the expiration date of the term of the
Lease is             ,             including any presently exercised option or renewal term, and that Tenant has no rights to
renew, extend or cancel the Lease or to lease additional space in the Premises or the Building, except as expressly set forth in the Lease;

(g) That in addition to the Premises, Tenant has the right to use or rent - parking spaces in or near the Building during the term of the Lease;

(h) That Tenant has no option or preferential right to purchase all or any part of the Premises (or the land or Building of which the
Premises are a part), and has no right or interest with respect to the Premises or the Building other than as Tenant under the Lease (except as specified in
                    , a copy of which is attached hereto);

(i) That all conditions of the Lease to be performed by Landlord and necessary to the enforceability of the Lease have been satisfied. On
this date there are no existing defenses, offsets, claims or credits which Tenant has against the enforcement of the Lease except for prepaid rent through             (not to exceed one
month);

(j) That all contributions required by the Lease to be paid by Landlord to date for improvements to the Premises
have been paid in full. All improvements or work required under the Lease to be made by Landlord to date, if any, have been completed to the satisfaction of Tenant. Charges for all labor and materials used or furnished in connection with
improvements and/or alterations made for the account of Tenant in the Building have been paid in full. Tenant has accepted the Premises, subject to no conditions other than those set forth in the Lease. Tenant has entered into occupancy of the
Premises;



75



---

(k) That the annual minimum rent currently payable under the Lease is
$            and such rent has been paid through                     ;

(l) [That additional rent is payable under the Lease for (i) operating, maintenance or repair expenses and (ii) property taxes.
The base year amounts for additional rental items are as follows: (1) operating, maintenance or repair expenses $            , and (2) property taxes
$            ;]

(m) That Tenant has made no agreement with
Landlord or any agent, representative or employee of Landlord concerning free rent, partial rent, rebate of rental payments or any other similar rent concession (except as expressly set forth in
            a copy of which is attached hereto). No rents have been prepaid more than one (1) month in advance and full rental, including basic minimum rent, if any, has commenced to
accrue;

(n) That to the best of Tenants knowledge, there are no defaults by Tenant or Landlord under the Lease, and
no event has occurred or situation exists that would, with the passage of time, constitute a default under the Lease;

(o)
That Tenant has paid to Landlord a security deposit in the amount of $

(p) That Tenant has all governmental permits, licenses and consents required for the activities and operations being conducted or to be conducted by it in or around the Building; and

(q) That as of this date there are no actions, whether voluntary or otherwise, pending against Tenant or any guarantor of the Lease under
the bankruptcy or insolvency laws of the United States or any state thereof.

2.    Tenant represents and warrants that
it has not used, generated, released, discharged, stored or disposed of any Hazardous Material on, under, in or about the Building or the land on which the Building is located, other than in the ordinary and commercially reasonable course of the
business of Tenant in compliance with all applicable laws. Except for any such legal and commercially reasonable use by Tenant, Tenant has no actual knowledge that any Hazardous Material is present or has been used, generated, released, discharged,
stored or disposed of by any party, on, under, in or about such Building or land, As used herein, Hazardous Material means any substance, material or waste (including petroleum and petroleum products) which is designated,
classified or regulated as being toxic or hazardous or a pollutant or which is similarly designated, classified or regulated under any federal, state or local law or ordinance.

3.    Tenant hereby agrees:

(a) To send a copy of any notice or demand given or made to Landlord pursuant to the provisions of the Lease to Bank of America, N.A. (Lender), who is or will be the owner and holder of a
mortgage or deed of trust on the demised premises, or its assignee upon being notified in writing of such assignees name and address. Lenders copy of said notice or demand shall be sent by certified mail at the same time the notice or
demand is sent to Landlord, to Bank of America, N.A., 700 Louisiana Street, 5th Floor, Houston, Texas 77002, Attention: Joyce Eng;

(b) To give to the holder of said mortgage or deed of trust a reasonable period of time, but in no event less than thirty (30) days, to cure any default complained of in said notice or demand;

(c) That no consent of Landlord to any modification or assignment of the Lease or any termination of the Lease (other than in accordance
with the express terms of the Lease) shall be effective without the prior written consent of the holder of said mortgage or deed of trust; and

(d) That in the event that the holder of said mortgage or deed of trust acquires title to the property encumbered by the mortgage or deed of trust, such holder will not be liable for any security deposit that Tenant
may have given to any previous landlord (including Landlord) which has not, as such, been transferred to such holder.



76



---

4.    Tenant acknowledges the right of Lender to rely upon the certifications and
agreements in this Certificate in making a loan to Landlord. Tenant hereby agrees to furnish Lender with such other and further estoppel certificates as Lender may reasonably request. Tenant understands that in connection with such loan,
Landlords interest in the rentals due under the Lease will be assigned to Lender pursuant to an assignment of leases by Landlord in favor of Lender. Tenant agrees that if Lender shall notify Tenant that a default has occurred under the
documents evidencing such loan and shall demand that Tenant pay rentals and other amounts due under the Lease to Lender, Tenant will honor such demand notwithstanding any contrary instructions from Landlord.

EXECUTED this             day of            ,
            .



By:Name:Title:




77



---

EXHIBIT G

WESTLAKE PARK PLACE

FORM SNDA

Subordination, Nondisturbance and Attornment Agreement

This SUBORDINATION, NONDISTURBANCE, AND ATTORNMENT AGREEMENT (this Agreement) is entered into as of             , 2007 (the
Effective Date), between Bank of America, N.A., a national banking association, whose address is 700 Louisiana 700, 5th Floor, Houston, Texas 77002, Attention: Joyce Eng, Attention: Commercial Real Estate Banking
(Mortgagee), and                     , a
                    , whose address is             (Tenant), with
reference to the following facts:

A.
                    , a                     ,
whose address is                     (Landlord), owns the real property located at
                    (such real property, including all buildings, improvements, structures and fixtures located thereon, Landlords
Premises), as more particularly described in Schedule A.

B. Mortgagee has made a loan to Landlord in the original
principal amount of $                     (the Loan).

C. To secure the Loan, Landlord has encumbered Landlords Premises by entering into that certain
                    dated             ,
200        , for the benefit of Mortgagee (as amended, increased, renewed, extended, spread, consolidated, severed, restated, or otherwise changed from time to time, the Mortgage) [to be]
recorded [on                     , at Book             , Page
            ,] in the land records of             County,
            (the Land Records).

D. Pursuant to a Lease,
dated as of             , 20        , as amended on
                    , 20            and
            , 20            (the Lease), Landlord demised to Tenant [a portion of] Landlords Premises
(Tenants Premises). Tenants Premises are commonly known as                     .

[E. A memorandum or short form of the Lease [is to be recorded in the Land Records prior to the recording of this Agreement.] [was recorded in the Land
Records on                     , at Book             , Page
            .]

F. Tenant and Mortgagee desire to agree upon the relative
priorities of their interests in Landlords Premises and their rights and obligations if certain events occur.

NOW, THEREFORE,
for good and sufficient consideration, Tenant and Mortgagee agree:



|1. | Definitions.
|-- | ------------

The following terms shall
have the following meanings for purposes of this Agreement.

1.1    Construction-Related Obligation. A
Construction-Related Obligation means any obligation of Landlord under the Lease to make, pay for, or reimburse Tenant for any alterations, demolition, or other improvements or work at Landlords Premises, including
Tenants Premises. Construction-Related Obligations shall not include: (a) reconstruction or repair following fire, casualty or condemnation; or (b) day-to-day maintenance and repairs.

1.2    Foreclosure Event. A Foreclosure Event means: (a) foreclosure under the Mortgage;
(b) any other exercise by Mortgagee of rights and remedies (whether under the Mortgage or under applicable law, including bankruptcy law) as holder of the Loan and/or the Mortgage, as a result of which Successor Landlord becomes owner of
Landlords Premises; or (c) delivery by Landlord to Mortgagee (or its designee or nominee) of a deed or other conveyance of Landlords interest in Landlords Premises in lieu of any of the foregoing.



78



---

1.3    Former Landlord. A Former Landlord means
Landlord and any other party that was landlord under the Lease at any time before the occurrence of any attornment under this Agreement.

1.4    Offset Right. An Offset Right means any right or alleged right of Tenant to any offset, defense (other than one arising from actual payment and performance, which payment and
performance would bind a Successor Landlord pursuant to this Agreement), claim, counterclaim, reduction, deduction, or abatement against Tenants payment of Rent or performance of Tenants other obligations under the Lease, arising
(whether under the Lease or other applicable law) from Landlords breach or default under the Lease.

1.5    Rent. The Rent means any fixed rent, base rent or additional rent under the Lease.

1.6    Successor Landlord. A Successor Landlord means any party that becomes owner of Landlords Premises as the result of a Foreclosure Event.

1.7    Termination Right. A Termination Right means any right of Tenant to cancel or terminate the
Lease or to claim a partial or total eviction arising (whether under the Lease or under applicable law) from Landlords breach or default under the Lease.



|2. | Subordination.
|-- | --------------

The Lease shall be, and
shall at all times remain, subject and subordinate to the Mortgage, the lien imposed by the Mortgage, and all advances made under the Mortgage.



|3. | Nondisturbance, Recognition and Attornment.
|-- | -------------------------------------------

3.1    No Exercise of Mortgage Remedies Against Tenant. So long as the Lease has not been terminated on account of Tenants default under the Lease that has continued beyond any applicable cure periods
set forth in the Lease (an Event of Default), Mortgagee shall not name or join Tenant as a defendant in any exercise of Mortgagees rights and remedies arising upon a default under the Mortgage unless applicable law requires
Tenant to be made a party thereto as a condition to proceeding against Landlord or prosecuting such rights and remedies. In the latter case, Mortgagee may join Tenant as a defendant in such action only for such purpose and not to terminate the Lease
or otherwise adversely affect Tenants rights under the Lease or this Agreement in such action.

3.2    Nondisturbance and Attornment. If the Lease has not been terminated on account of an Event of Default by Tenant, then, when Successor Landlord takes title to Landlords Premises:
(a) Successor Landlord shall not terminate or disturb Tenants possession of Tenants Premises under the Lease, except in accordance with the terms of the Lease and this Agreement; (b) Successor Landlord shall be bound to Tenant
under all the terms and conditions of the Lease (except as provided in this Agreement); (c) Tenant shall recognize and attorn to Successor Landlord as Tenants direct landlord under the Lease as affected by this Agreement; and (d) the
Lease shall continue in full force and effect as a direct lease, in accordance with its terms (except as provided in this Agreement), between Successor Landlord and Tenant.

3.3    Further Documentation. The provisions of this Section shall be effective and self-operative without any need for
Successor Landlord or Tenant to execute any further documents. Tenant and Successor Landlord shall, however, confirm the provisions of this Section in writing upon request by either of them.

4.Protection of Successor Landlord.

Notwithstanding anything to the contrary in the Lease or the Mortgage, Successor Landlord shall not be liable for or bound by any of the following matters:

4.1    Claims Against Former Landlord. Any Offset Right that Tenant may have against any Former Landlord relating to any
event or occurrence before the date of attornment, including any claim for damages of



79



---

any kind whatsoever as the result of any breach by Former Landlord that occurred before the date of attornment. (The foregoing shall not limit either
(a) Tenants right to exercise against Successor Landlord any Offset Right otherwise available to Tenant because of events occurring after the date of attornment or (b) Successor Landlords obligation to correct any conditions
that existed as of the date of attornment and violate Successor Landlords obligations as landlord under the Lease.)

4.2    Prepayments. Any payment of Rent that Tenant may have made to Former Landlord more than thirty days before the date such Rent was first due and payable under the Lease with respect to any period
after the date of attornment other than, and only to the extent that, the Lease expressly required such a prepayment.

4.3    Payment; Security Deposit. Any obligation: (a) to pay Tenant any sum(s) that any Former Landlord owed to Tenant or (b) with respect to any security deposited with Former Landlord, unless
such security was actually delivered to Mortgagee. This paragraph is not intended to apply to Landlords obligation to make any payment that constitutes a Construction-Related Obligation.

4.4    Modification, Amendment, or Waiver. Any modification or amendment of the Lease, or any waiver of any terms of
the Lease, made without Mortgagees written consent.

4.5    Surrender, Etc. Any consensual or
negotiated surrender, cancellation, or termination of the Lease, in whole or in part, agreed upon between Landlord and Tenant, unless effected unilaterally by Tenant pursuant to the express terms of the Lease.

4.6    Construction-Related Obligations. Any Construction-Related Obligation of Landlord under the Lease, except as
expressly provided for in Schedule B (if any) attached to this Agreement.

5.Exculpation of Successor
Landlord.

Notwithstanding anything to the contrary in this Agreement or the Lease, upon any attornment pursuant to this
Agreement the Lease shall be deemed to have been automatically amended to provide that Successor Landlords obligations and liability under the Lease shall never extend beyond Successor Landlords (or its successors or assigns)
interest, if any, in Landlords Premises from time to time, including insurance and condemnation proceeds, Successor Landlords interest in the Lease, and the proceeds from any sale or other disposition of Landlords Premises by
Successor Landlord (collectively, Successor Landlords Interest). Tenant shall look exclusively to Successor Landlords Interest (or that of its successors and assigns) for payment or discharge of any obligations of
Successor Landlord under the Lease as affected by this Agreement. If Tenant obtains any money judgment against Successor Landlord with respect to the Lease or the relationship between Successor Landlord and Tenant, then Tenant shall look solely to
Successor Landlords Interest (or that of its successors and assigns) to collect such judgment. Tenant shall not collect or attempt to collect any such judgment out of any other assets of Successor Landlord.

6.Mortgagees Right to Cure.

6.1    Notice to Mortgagee. Notwithstanding anything to the contrary in the Lease or this Agreement, before exercising any Termination Right or Offset Right, Tenant shall provide
Mortgagee with notice of the breach or default by Landlord giving rise to same (the Default Notice) and, thereafter, the opportunity to cure such breach or default as provided for below.

6.2    Mortgagees Cure Period. After Mortgagee receives a Default Notice, Mortgagee shall have a period of thirty
days beyond the time available to Landlord under the Lease in which to cure the breach or default by Landlord. Mortgagee shall have no obligation to cure (and shall have no liability or obligation for not curing) any breach or default by Landlord,
except to the extent that Mortgagee agrees or undertakes otherwise in writing.



80



---

6.3    Extended Cure Period. In addition, as to any breach or default
by Landlord the cure of which requires possession and control of Landlords Premises, provided only that Mortgagee undertakes to Tenant by written notice to Tenant within thirty days after receipt of the Default Notice to exercise reasonable
efforts to cure or cause to be cured by a receiver such breach or default within the period permitted by this paragraph, Mortgagees cure period shall continue for such additional time (the Extended Cure Period) as Mortgagee
may reasonably require to either (a) obtain possession and control of Landlords Premises and thereafter cure the breach or default with reasonable diligence and continuity or (b) obtain the appointment of a receiver and give such
receiver a reasonable period of time in which to cure the default.

7.Confirmation of Facts.

Tenant represents to Mortgagee and to any Successor Landlord, in each case as of the Effective Date:

7.1    Effectiveness of Lease. The Lease is in full force and effect, has not been modified, and constitutes the entire
agreement between Landlord and Tenant relating to Tenants Premises. Tenant has no interest in Landlords Premises except pursuant to the Lease. No unfulfilled conditions exist to Tenants obligations under the Lease.

7.2    Rent. Tenant has not paid any Rent that is first due and payable under the Lease after the Effective Date.

7.3    No Landlord Default. To the best of Tenants knowledge, no breach or default by Landlord
exists and no event has occurred that, with the giving of notice, the passage of time or both, would constitute such a breach or default.

7.4    No Tenant Default. Tenant is not in default under the Lease and has not received any uncured notice of any default by Tenant under the Lease.

7.5    No Termination. Tenant has not commenced any action nor sent or received any notice to terminate the Lease.
Tenant has no presently exercisable Termination Right(s) or Offset Right(s).

7.6    Commencement Date.
The Commencement Date of the Lease was             .

7.7    Acceptance. Except as set forth in Schedule B (if any) attached to this Agreement: (a) Tenant has accepted possession of Tenants Premises; and (b) Landlord has performed all
Construction-Related Obligations related to Tenants initial occupancy of Tenants Premises and Tenant has accepted such performance by Landlord.

7.8    No Transfer. Tenant has not transferred, encumbered, mortgaged, assigned, conveyed or otherwise disposed of the Lease or any interest therein, other than sublease(s) made in
compliance with the Lease.

7.9    Due Authorization. Tenant has full authority to enter into this
Agreement, which has been duly authorized by all necessary actions.

8.Miscellaneous.

8.1    Notices. All notices or other communications required or permitted under this Agreement shall be in writing and
given by certified mail (return receipt requested) or by nationally recognized overnight courier service that regularly maintains records of items delivered. Each partys address is as set forth in the opening paragraph of this Agreement,
subject to change by notice under this paragraph. Notices shall be effective the next business day after being sent by overnight courier service, and five business days after being sent by certified mail (return receipt requested).



81



---

8.2    Successors and Assigns. This Agreement shall bind and benefit
the parties, their successors and assigns, any Successor Landlord, and its successors and assigns. If Mortgagee assigns the Mortgage, then upon delivery to Tenant of written notice thereof accompanied by the assignees written assumption of all
obligations under this Agreement, all liability of the assignor shall terminate.

8.3    Entire
Agreement. This Agreement constitutes the entire agreement between Mortgagee and Tenant regarding the subordination of the Lease to the Mortgage and the rights and obligations of Tenant and Mortgagee as to the subject matter of this
Agreement.

8.4    Interaction with Lease and with Mortgage. If this Agreement conflicts with the Lease,
then this Agreement shall govern as between the parties and any Successor Landlord, including upon any attornment pursuant to this Agreement. This Agreement supersedes, and constitutes full compliance with, any provisions in the Lease that provide
for subordination of the Lease to, or for delivery of nondisturbance agreements by the holder of, the Mortgage. Mortgagee confirms that Mortgagee has consented to Landlords entering into the Lease.

8.5    Mortgagees Rights and Obligations. Except as expressly provided for in this Agreement, Mortgagee shall
have no obligations to Tenant with respect to the Lease. If an attornment occurs pursuant to this Agreement, then all rights and obligations of Mortgagee under this Agreement shall terminate, without thereby affecting in any way the rights and
obligations of Successor Landlord provided for in this Agreement.

8.6    Interpretation; Governing Law.
The interpretation, validity and enforcement of this Agreement shall be governed by and construed under the internal laws of the State of California, excluding its principles of conflict of laws.

8.7    Amendments. This Agreement may be amended, discharged or terminated, or any of its provisions waived, only by a
written instrument executed by the party to be charged.

8.8    Execution. This Agreement may be executed
in any number of counterparts, each of which shall be deemed an original and all of which together shall constitute one and the same instrument.

8.9    Mortgagees Representation. Mortgagee represents that Mortgagee has full authority to enter into this Agreement, and Mortgagees entry into this Agreement has been duly authorized by all
necessary actions.

IN WITNESS WHEREOF, this Agreement has been duly executed and sealed by Mortgagee and Tenant as of the Effective Date.



MORTGAGEEBank of America, N.A., a national banking associationBy:Name:Title:[BANK SEAL]




82



---

TENANT,


a



corporation


By:Name:Title:[CORPORATE SEAL]




83



---

|          |  |  |  |   |  |   |  |    
|--------- |  |  |  | - |  | - |  | ---
|STATE
OF  |  |  |  | ) |  |  
|          |  |  |  |   |  | ) |  | ss.
|COUNTY OF |  |  |  | ) |  |  

The foregoing instrument was acknowledged before me this
                    day of                     ,
200    , by                     ,
                     of                     ,
                    .

Witness my hand
and official seal.



|                       |  |  |  | 
|---------------------- |  |  |  | 
|My commission expires: |  |  |  | 
|                       |  |  |  | 



| |  |  |  |              
| |  |  |  | -------------
| |  |  |  |              
| |  |  |  | Notary Public



|          |  |  |  |   |  |   |  |    
|--------- |  |  |  | - |  | - |  | ---
|STATE
OF  |  |  |  | ) |  |  
|          |  |  |  |   |  | ) |  | ss.
|COUNTY OF |  |  |  | ) |  |  

The foregoing instrument was acknowledged before me this
                    day of                     ,
200    , by                     ,
                     of                     ,
                    .

Witness my hand
and official seal.



|                       |  |  |  | 
|---------------------- |  |  |  | 
|My commission expires: |  |  |  | 
|                       |  |  |  | 



| |  |  |  |              
| |  |  |  | -------------
| |  |  |  |              
| |  |  |  | Notary Public



84



---

LANDLORDS CONSENT

Landlord consents and agrees to the foregoing Agreement, which was entered into at Landlords request. The foregoing Agreement shall not alter, waive or diminish any of Landlords obligations under the
Mortgage or the Lease. The above Agreement discharges any obligations of Mortgagee under the Mortgage and related loan documents to enter into a nondisturbance agreement with Tenant. Landlord is not a party to the above Agreement.



LANDLORD


,


a



corporation


By:Name:Title:


Dated:



,

20


[CORPORATE SEAL]




|          |  |  |  |   |  |   |  |    
|--------- |  |  |  | - |  | - |  | ---
|STATE
OF  |  |  |  | ) |  |  
|          |  |  |  |   |  | ) |  | ss.
|COUNTY OF |  |  |  | ) |  |  



|                                                                                                                                                                                                    
|----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
|The foregoing instrument was acknowledged before me this          day of
                    , 200    , by
                    ,                      of
                    ,
                    .

Witness my hand and official seal.



|                       |  |  |  | 
|---------------------- |  |  |  | 
|My commission expires: |  |  |  | 
|                       |  |  |  | 



| |  |               |  | 
| |  | ------------- |  | 
| |  |               |  | 
| |  | Notary Public |  | 



85



---

SCHEDULE A

TO

EXHIBIT G

Description of Landlords Premises



86



---

SCHEDULE B

TO

EXHIBIT G

Construction-Related Obligations

A.
Construction-Related Obligations Remaining to be Performed as of Effective Date.

[Summarize and Describe]

B. Successor Landlords Construction-Related Obligations After Attornment.

[None]



87



---

EXHIBIT H

WESTLAKE PARK PLACE

RULES AND REGULATIONS

1. Rights of Entry. Tenant will have the right to enter the Premises at any time, but outside of Business Hours Tenant will be required to furnish
proper and verifiable identification. Landlord will have the right to enter the Premises after Business Hours to perform janitorial services not otherwise the obligation of Tenant under the Lease, at all reasonable hours to clean windows and
also at any time during the last three months of the Term, with reasonable prior notice to Tenant, to show the Premises to prospective tenants.

2. Right of Exclusion. Landlord reserves the right to exclude or expel from the Project any person who, in Landlords reasonable judgment, is intoxicated or under the influence of alcohol or drugs.

3. Obstructions. Tenant will not obstruct or place anything in or on the sidewalks or driveways outside the Building, or in the lobbies,
corridors, stairwells or other Common Areas. Landlord may remove, at Tenants expense, any such obstruction or thing without notice or obligation to Tenant.

4. Refuse. Tenant will place all refuse in the Premises in proper receptacles provided and paid for by Tenant, or in receptacles provided by Landlord for the Project, and will not place any litter or refuse on
or in the sidewalks or driveways outside the Building, or the Common Areas, lobbies, corridors, stairwells, ducts or shafts of the Building.

5. Public Safety. Tenant will not throw anything out of doors, windows or skylights, down passageways or over walls.

6.
Keys; Locks. Landlord may from time to time install and change locks on entrances to the Building, Common Areas and the Premises, and will provide Tenant a reasonable number of keys to meet Tenants requirements. If Tenant desires
additional keys they will be furnished by Landlord and Tenant will pay a reasonable charge for them. Tenant will not add or change existing locks on any door in or to the Premises without Landlords prior written consent. If with
Landlords consent, Tenant installs lock(s) incompatible with the Building master locking system:

a. Landlord, without
abatement of Rent, will be relieved of any obligation under the Lease to provide any service that requires access to the affected areas;

b. Tenant will indemnify Landlord against any expense as a result of forced entry to the affected areas which may be required in an emergency; and

c. Tenant will, at the end of the Term and at Landlords request, remove such lock(s) at Tenants expense.

At the end of the Term, Tenant will promptly return to Landlord all keys for the Building and Premises which are in Tenants possession.

7. Aesthetics. Subject to Section 21 and Exhibit J, Tenant will not attach any awnings, signs, displays or
projections to the outside or inside walls or windows of the Building which are visible from outside the Premises without Landlords prior written approval, which may be withheld in Landlords sole discretion.

8. Window Treatment. Subject to Exhibit D, if Tenant desires to attach or hang any curtains, blinds, shades or screens to
or in any window or door of the Premises, Tenant must obtain Landlords prior written approval. Tenant will not coat or sunscreen the interior or exterior of any windows without Landlords express written consent. Tenant will not place any
objects on the window sills that cause, in Landlords reasonable opinion, an aesthetically unacceptable appearance.



88



---

9. Directory Boards. Subject to Section 21 and Exhibit J, Landlord
will make every reasonable effort to accommodate Tenants requirements for the Building directory boards. The cost of any changes to the directory board information identifying Tenant requested by Tenant subsequent to the initial installation
of such information will be paid for by Tenant.

10. Project Control. Landlord reserves the right to control and operate the Common
Areas as well as facilities furnished for the common use of tenants in such manner as Landlord deems best for the benefit of tenants generally. Landlord reserves the right to prevent access to the Project or any portion thereof during an emergency
by closing the doors or otherwise, for the safety of tenants and protection of the Project and property in the Project.

11. Engineering
Consent. All plumbing, electrical and heating, ventilating and air conditioning (HVAC) work for and in the Premises requires Landlords prior written consent to maintain the integrity of the Projects electrical,
plumbing and HVAC systems.

12. HVAC Interference. Tenant will not place objects or other obstructions on the HVAC convectors or
diffusers and will not permit any other interference with the HVAC system.

13. Plumbing. Tenant will only use plumbing fixtures for
the purpose for which they are constructed. Tenant will pay for all damages resulting from any misuse by Tenant of plumbing fixtures.

14.
Equipment Location. Landlord reserves the right to specify where Tenants business machines, mechanical equipment and heavy objects will be placed in the Premises in order to best absorb and prevent vibration, noise and annoyance to
other tenants, and to prevent damage to the Building and/or the Project; provided, however, that to the extent (i) Tenants Working Drawings and/or Construction Documents specify the location of such objects, (ii) Tenant specifically
notifies Landlord in writing that Tenant intends to place such objects in the locations set forth in the Working Drawings and/or Construction Drawings, and (iii) Landlord approves the same in accordance with the Work Letter, then such action
shall constitute Landlords approval of the location within the Premises of such objects. Tenant will pay the cost of any required professional engineering certification or assistance.

15. Bicycles; Animals. Tenant will not bring into, or keep about, the Premises any bicycles, vehicles, birds, animals or organic Christmas
décor of any kind. Bicycles and vehicles may only be parked in areas designated for such purposes.

16. Carpet Protection. In
those portions of the Premises where carpet has been provided by Landlord, Tenant will at its own expense install and maintain pads to protect the carpet under all furniture having castors other than carpet castors.

17. Proper Conduct. Tenant will conduct itself in a manner which is consistent with the character of the Project and will ensure that
Tenants conduct will not impair the comfort or convenience of other tenants in the Project.

18. Elevators. Except as may be
expressly permitted by Landlord, only freight elevators may be used for deliveries. Use of freight elevators after Business Hours must be scheduled through the office of Property Manager.

19. Deliveries. Tenant will ensure that deliveries of materials and supplies to the Premises are made through such entrances, elevators and
corridors and at such times as may from time to time be reasonably designated by Landlord. Such deliveries may not be made through any of the main entrances to the Project without Landlords prior permission. Tenant will use or cause to be
used, in the Building, hand trucks or other conveyances equipped with rubber tires and rubber side guards to prevent damage to the Building or property in the Building. Tenant will promptly pay Landlord the cost of repairing any damage to the
Building and/or the Project caused by any person making deliveries to the Premises.



89



---

20. Moving. Tenant will ensure that furniture and equipment and other bulky matter being moved to
or from the Premises are moved through such entrances, elevators and corridors and at such times as may from time to time be reasonably designated by Landlord, and by movers or a moving company reasonably approved by Landlord. Tenant will promptly
pay Landlord the cost of repairing any damage to the Building and/or the Project caused by any person moving any such furniture, equipment or matter to or from the Premises other than those caused by Landlord or any Landlord Parties.

21. Solicitations. Canvassing, soliciting and peddling in the Project are prohibited and Tenant will cooperate in preventing the same.

22. Food. Only persons approved from time to time by Landlord may prepare, solicit orders for, sell, serve or distribute food in or around the
Project. Except as may be specified in the Lease or on construction drawings for the Premises approved by Landlord, and except for microwave cooking, Tenant will not use the Premises for preparing or dispensing food, or soliciting of orders for
sale, serving or distribution of food.

23. Smoking. The smoking of cigarettes, cigars, pipes, etc. is STRICTLY PROHIBITED anywhere
in the interior of the Building including the Premises. The ONLY designated smoking areas will be specifically designated by Landlord. STANDING ASH TRAYS WILL BE PROVIDED.

24. Chemical Storage. All chemicals, paints or other similar materials must be stored either in a fire proof cabinet in compliance with all Laws,
including all applicable fire codes, or in a location outside the Building. Nothing in this paragraph will permit Tenant to violate Section 4 of the Lease.

25. Storage Near Ceiling. Tenant may not store any materials within 18 inches (or any greater distance prescribed, from time to time, by Laws, including applicable fire codes) of the ceiling of the
Premises.

26. Employees, Agents and Invitees. In these Rules and Regulations, Tenant includes Tenants
employees, agents, invitees, licensees and others permitted by Tenant to access, use or occupy the Premises.



90



---

EXHIBIT I

WESTLAKE PARK PLACE

TELECOMMUNICATIONS RULES

These Telecommunications Rules apply to Tenants use of the Building and the Project outside of the Premises, including, without limitation, the
telecommunications closets (each, a TC) on each floor of the Building, the plenum space above the finished or drop ceiling above the Premises, the space in the Common-Areas and roof space. Any questions about what is
allowed in the Building should be directed to Property Manager.

A. WRITTEN AGREEMENT REQUIRED.

1. Tenant will be required to secure Property Managers approval before installing any cable or wire outside the Premises and/or in, through or to
any TC.

2. To the extent required by Landlord but subject to the terms of the Lease, and before any new installations are commenced, even
if Tenant has existing facilities in the Building, (i) either Tenant or Tenants telecommunications provider shall enter into an agreement with Landlord, with the form and substance of such agreement being acceptable to Landlord and Tenant
or Tenants telecommunications providers, as applicable, in each partys reasonable discretion and (ii) Tenants telecommunication provider shall provide Landlord with proof of insurance in such amounts and such coverage as
Landlord may reasonably require. Wires or cable installed without such agreement are subject to removal by Property Manager, at Tenants sole cost.

3. Neither Landlord, Property Manager nor any of their respective employees, contractors or agents will be responsible for any damage or theft to Tenant equipment.

B. INSTALLATION AND OTHER WORK.

1. Tenant will give
Property Manager prior notice, in writing or by email, of all times that Tenant will work in or will have work done in the TC, on the roof, or outside the Premises. Such notice will include the purpose and detail of the work to be done, as well as
the day and time the work will be performed.

2. Subject to the terms of the Lease, all welding and/or core drilling or installation of
equipment on the roof must be approved by Property Manager in writing prior to any of the work being started. Property Manager will require drawing(s) and detailed information on any welding and/or core drilling or installation of equipment on the
roof. Property Manager requires a minimum of one week for this review process. All floors requiring core drilling must be x rayed to determine placement of core drill locations. Property Manager reserves the right, in its sole and absolute
discretion, to deny approval of any requested core drilling or welding, and Property Manager will have the right to supervise any and all such drilling and/or welding.

C. LOCATION OF EQUIPMENT.

1. No Tenant-owned or leased telecommunications equipment (i.e., PBXs
key service units, hubs, bridges, amplifiers/paging equipment, routers, cable TV, security systems, patch panel or storage of any kind) will be located in a TC. The TCs are not designed to handle the operation of electronic computing or
communication equipment, but only to allow Tenant to connect to carrier or provider service.

2. All telecommunications equipment
(including blocks and brackets) owned and controlled by Tenant will be located in the Premises, and Tenant will be solely responsible for control of access to, security of and maintenance of such equipment. Notwithstanding the foregoing, if Tenant
has already installed its equipment in a TC, it will not be required to remove it, but if Tenant relocates or expands the Premises within the Building, it will be required to move its telecommunications equipment into the Premises.



91



---

3. All station wiring for individual telephones, fax machines, modems, Local Area Networks (each a
LAN) and similar equipment will be terminated within the Premises. No LAN equipment, such as concentrators and patch panels, will be installed in a TC.

4. Subject to the terms of the Lease, any equipment to be placed on the roof must be approved in writing by Property Manager as to weight, specification, placement, mounting assembly and any other pertinent features.
Any roof penetrations require the written approval of Property Manager with the work to be performed by Property Managers designated roofing contractor, and supervised by the Projects chief engineer, all at Tenants expense.

D. SPECIFICATIONS.

1. If Tenant has
not yet occupied the Premises, Tenant will install, or cause to be installed, at Tenants sole cost, a minimum of 3/4 non-combustible plywood back board for mounting wiring blocks, telephone system and other peripheral equipment. The
backboard must be painted with two coats of fire retardant paint matching the Tenants room decor. A wall-to-floor mounted rack designed for this purpose may be substituted for the backboard. Tenant will be responsible for all costs.

2. Tenant will provide a minimum of one plenum-rated or FEP rated 25-pair cable for connecting its equipment room to the floor TC. For
building housekeeping reasons and management of the Premises, only cables with 25-pair or more cables will be permitted to connect the Premises and a floor TC. Each such cable (a) will be supported and attached in an approved manner and meet
all requirements for firewall penetration, (b) be equipped with a male 50 pin connector at the TC end, and (c) be plugged into a standard RJ21X block with an orange-hinged cover. This block will be labeled with Tenants
name and suite number(s), and each circuit will be properly labeled.

3. All Tenant horizontal cabling installed within the Premises will
be installed as per TIA/EIA 568 A standards unless otherwise approved in writing by Property Manager.

4. All wire and cable installed
above ceilings will be plenum-rated cable or limited combustion cable known as FEP rated cable, be properly supported or attached to the Building on their own hangers designed specifically for low voltage wire support, and be
labeled with Tenants name, contact person and telephone number. Tenant will install, or cause to be installed, all wires, cables and their connections installed in compliance with all applicable governmental codes, rules, regulations and laws.

5. Tenant will cause all new installations in common areas of the Project to be contained in raceway (EMT or rigid conduit) with the
outside of the raceway properly located in accordance with the aforementioned standards. Tenant can be exempt from using raceway if and only if such exemption is specifically contained in a written license agreement referred to in Section A.2
of this Exhibit I.

6. If a pull box is required because of distances or bends, a locking pull box must be
installed. The pull box must identify Tenant, the pull boxs contents and a contact person.

E. PLANS AND DIAGRAMS.

1. Tenant will provide Property Manager with a wiring diagram (including a riser diagram) of the Premises showing all cable numbers and locations upon
completion of any new cable systems installation. Tenant will provide to Property Manager with a set of as-built drawings upon completion of any new cable systems. Tenant must update such drawings with any changes, deletions or additions to
Tenants service and/or equipment during the Term.

2. Tenant will provide to Property Manager a diagram of any existing cabling in
the Premises, showing locations and numbers. This information will be submitted to Property Manager prior to the space being vacated.



92



---

F. REMOVAL.

1. Wires and cables installed by or for Tenant will be removed at the expense of Tenant at the end of the Term, unless Landlord agrees otherwise in writing. Failure to comply with this requirement could lead to Property Manager removing the
wires, cabling and/or equipment and charging Tenant and/or could lead to Tenant being cited and fined by the local Building Department and/or Fire Department.

2. All wires, cables and associated equipment installed by or for the Tenant that are abandoned in place (as that phrase is defined by the 2002 and/or 2005 National Electric Code
(NEC)) will be removed by the Tenant immediately after the wires, cables and/or equipment becomes abandoned in place. Tenant will not wait until the expiration of the Lease to remove abandoned wires, cabling and equipment.

3. Any unidentified or terminated cable and/or equipment located in the Project and outside of a tenants premises, including in a TC
or on the roof, becomes the property of Landlord and, as such, can be removed and disposed by Property Manager at its sole discretion.

G. GENERALLY.

1. Other than during construction of the Leasehold Improvements, Tenant and its employees, contractors and agents will comply with
Property Managers sign-out/sign-in system for access to the TCs and/or the roof.

2. All capitalized terms not defined herein
have the meanings given them in the Lease. In the event of any conflict or ambiguity between the terms of these Rules and the Lease, the terms of the Lease will govern.

3. These Rules may be updated, amended or otherwise modified from time to time in the discretion of Landlord.

4. All contractors will comply with the Project contractors rules and regulations.

H. INSTALLATION AND USE OF WIRELESS TECHNOLOGIES.

Tenant will not utilize any wireless communications equipment (other than usual and customary cellular telephones), including antennae
and/or satellite receiver dishes, within the Premises, the Building and/or the Project without Landlords prior written consent. Such consent may be conditioned in such a manner so as to protect Landlords financial interests and the
interests of the Project, and the other tenants therein, in a manner similar to the arrangements described in the immediately preceding paragraphs. Such consent may, at Landlords election, be in the form of a telecommunications license
agreement (Telecommunications Agreement) between Landlord and Tenant. If required by Landlord, the Telecommunications Agreement must be executed before Tenant will be permitted to install and/or operate any wireless system in the
Project or in the Premises. Such wireless systems would include, without limitation, a wireless local area network, a metropolitan wireless network between buildings, a building antenna system to boost and enhance operation of cellular (analog
and/or digital) phones or any wireless system with transmission capability.

I. ACCESS TO AREAS OUTSIDE THE PREMISES.

The Lease does not give Tenant the right to access any areas outside of the Premises (such as space above the drop ceiling within the Premises, ceiling
above hallways, dedicated telecommunications/electrical power closets, utility risers, etc.) for purposes of installation of any telecommunications equipment (referred to herein as the Project Telecommunications Areas). The
Project Telecommunications Areas are critical space for the Building systems and are not intended for installation of Tenants, vendors or service providers equipment. However, Landlord, upon Tenants written request and
subject to availability and any other conditions that Landlord may impose in its sole discretion, may approve Tenants use of certain Project Telecommunications Areas for the purposes of installation of cabling or wiring from one area of the
Premises to another. In the event



93



---

that Tenant desires such use and Landlord approves the same, Tenants right to use any portion of the Project Telecommunications Areas may, at
Landlords option, be subject to Tenant entering into a Telecommunications Agreement reasonably acceptable to Landlord and Tenant. If required by Landlord and subject to the terms of the Lease, the Telecommunications Agreement must be executed
before Tenant will be permitted to install any cabling or other equipment in any portion of the Project Telecommunications Areas. Notwithstanding anything to the contrary contained herein, in any Telecommunications Agreement or in the Lease, any
cabling installed in the Premises or elsewhere in the Project by or for the use of Tenant will be removed by Tenant, at Tenants sole cost, at such time that the cabling is no longer in use.



94



---

EXHIBIT J

LOGO



95



---

LOGO



96



---

LOGO



97



---

EXHIBIT K

WESTLAKE PARK PLACE

PARKING RULES AND REGULATIONS

The following rules and regulations shall govern the use of the parking facilities designated in the Lease in connection with the use
of the Premises.

1. Landlord assumes no responsibility for any damage to any vehicle parked in the parking areas or for any goods left in
any such vehicle. All such liability is specifically assumed by the operator of any such vehicle as a condition of parking.

2. Tenant
shall not (a) park or permit its employees to park in any parking areas designated by Landlord as areas for parking by visitors to the Project, (b) park or permit its employees, guests, invitees or visitors to park in the residential or
commercial neighborhoods contiguous to the Project, (c) leave vehicles in the parking areas overnight, or (d) park any vehicles in the parking areas other than automobiles, motorcycles, motor driven or non-motor driven bicycles or four
wheeled trucks. No propane or natural gas powered vehicles shall be allowed to park in the parking areas.

3. Parking cards, stickers, or
any other devices or forms of identification supplied by Landlord as a condition of use of the parking facilities shall remain the property of Landlord. Such parking identification device must be displayed as requested and may not be mutilated in
any manner. The serial number of the parking identification device may not be obliterated. Devices are not transferable and any device in the possession of an unauthorized holder will be void. Landlord reserves the right to (a) require that a
reasonable security deposit be paid to Landlord for each parking area or Building access card issued to Tenant, and (b) change the location of Tenants reserved parking spaces, if any, from time to time.

4. No overnight or extended term storage of vehicles shall be permitted.

5. Vehicles must be parked entirely within painted stall lines of a single parking stall.

6. All
directional signs and arrows must be observed.

7. The speed limit within all parking areas shall be five (5) miles
per hour.

8. Parking is prohibited in any area other than those specifically designated for parking.

9. All parkers are required to park and lock their own vehicles. All responsibility for damage to vehicles is assumed by the parker.

10. Loss or theft of parking identification devices must be reported to Landlords asset management office for the Project immediately, and a lost
or stolen report must be filed by the Tenant or user of such parking identification device at the time. Landlord has the right to exclude any vehicle from the parking facilities that does not have an identification device.

11. Any parking identification devices reported lost or stolen found on any unauthorized vehicle will be confiscated and the illegal holder will be
subject to prosecution.

12. Washing, waxing, cleaning or servicing of any vehicle in any area not specifically reserved for such purpose
is prohibited.

13. The parking operators, managers or attendants are not authorized to make or allow any exceptions to these rules and
regulations.



98



---

14. Tenants continued right to use any parking spaces in the parking facilities is conditioned upon
Tenant abiding by these rules and regulations and those contained in this Lease. Further, if this Lease terminates for any reason whatsoever, Tenants right to use the parking spaces in the parking facilities shall terminate concurrently with
the Lease.

15. Tenant agrees to sign a parking agreement with Landlord or Landlords parking operator within five (5) days
of request, which agreement shall provide the manner of payment of monthly parking fees and otherwise be consistent with this Lease and these rules and regulations.

16. Landlord reserves the right to refuse the sale of parking cards, stickers or other parking identification devices to any tenant or person or their respective agents or representatives who willfully refuse to
comply with these rules and regulations and all posted or unposted city, state or federal ordinances, laws or agreements.

17. Tenant and
its employees shall comply with any traffic management and/or environmental regulation program now or hereafter in effect, whether imposed by local, regional, state or federal governmental or quasi-governmental agencies (collectively, TDM
Program) which has been or may hereafter be applicable to Tenant, the Building or the Project. Tenant acknowledges that such a TDM Program may cause Tenant inconvenience, but nonetheless agrees to cooperate in the formation of, and comply
with the provisions of, any such TDM Program. Additionally, Tenant shall (a) participate in any employee commute transportation surveys reasonably required by Landlord, and (b) adhere to measures that Landlord may enact in order to comply
with existing and future laws relating to traffic control or flow applicable to the Project. Any breach by Tenant of any of its covenants in this Paragraph 17 may result in penalty fees being assessed against Landlord; therefore, Tenant shall
be liable to Landlord for all such fees, plus interest thereon, assessed on account of any such breach, and that breach shall also constitute a material default under this Lease.

18. Landlord reserves the right to establish and change parking fees and to modify these rules and regulations or adopt such other reasonable and
nondiscriminatory rules and regulations for the parking facilities as it deems necessary for the operation of the parking facilities. Landlord may refuse to permit any person who violates these rules to park in the parking facilities, and any
violation of the rules shall subject the vehicle to removal at such vehicle owners expense.



99



---

EXHIBIT L

WESTLAKE PARK PLACE

JANITORIAL SPECIFICATIONS

SCOPE OF WORK



|                                          |  |                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                           
|----------------------------------------- |  | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
|Lobby and Corridors Cleaning Requirements |  | Daily Services Five Days Per
Week       Clean, detail and sanitize all public telephones and enclosures. (Neatly arrange all phone books).       Clean and remove smudges from entry door glass.       Polish all entry
handles, doorplates and metal trim.       Empty all ashtrays and wipe clean and polish. Screen all sand urns or butts and debris.       Empty all trash receptacles, clean container with clean, damp cloth and replace plastic
liners.       Dust and clean all horizontal surfaces under seven (7) feet.       Vacuum all carpet areas.       Dust mop or damp mop
entry floors.       Clean, polish and sanitize all water fountains.       Clean and polish all elevator doors, jambs, call plates and hall lanterns.       Clean, polish and
straighten all furniture as needed.       Dust and clean all lobby and corridor signage.       Report any lights burned out.       Secure all doors and
turn-off appropriate lights upon completion of work assignments.  Weekly
Services       Replace sand in ash urns weekly or as needed.       Clean and remove smudges and marks on walls, and wall coverings.       Wipe clean all fire
extinguisher cabinets and glass. (Report broken glass or missing extinguisher.)       Dust and clean all baseboards.       Spot clean all carpeted
areas.       Dust all ledges and exit signs.  Monthly Services       Dust high ceiling corners and entryways.       Scrub and wax all tile floors. (Not to be slippery).



100



---

|                                          |  |                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                       
|----------------------------------------- |  | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
|                                          |  | Quarterly Services       Clean all ceiling vents and grills.       Dust and clean light
fixtures and covers.       Strip and wax common area floors.                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                               
|                                          | 
|General Office Area Cleaning
Requirements |  | Daily Services Five Days Per
Week       Waste baskets emptied and replaced with new liners, if soiled.       As needed, dust furniture (file cabinets, tables, credenzas, etch), tops only, and only when
free of papers, folders, etc.       Traffic areas to be policed for scraps of paper, paper clips, etc.       Tile floors and door thresholds swept and/or dust mopped.       Carpeted floors spot
cleaned and vacuumed.       Spot clean to remove smudges, finger marks from doors, walls, partitions, glass, file cabinets, light switch plates, etc.       Glass doors, clean finger marks from both sides.       Properly position, books
and magazines in reception areas.       Properly position furniture in offices and conference rooms.       Dust and replace all desk ornaments, phones and machines to their ORIGINAL
POSITION.       Clean and wash all lunchroom tabletops, counters, cabinets, refrigerator, and stove (outside only) surfaces. (Report any insect problem).       Before leaving any
suite, shut-off lights, electrical appliances, and lock all entrance doors.       Report all burned out lights.  Weekly Services       Low dusting, including all chair legs, backboards, furniture legs and other areas of furniture and accessories not dusted during nightly dusting.       Telephones wiped clean.       Thoroughly vacuum entire carpeted areas. Remove staples and other debris.       Damp mop all tile and hardwood floor areas.       Dust windowsills and
ledges.  Monthly Services       Detail vacuuming of all
carpeted areas, including edging, corners, behind doors and vacuuming under desks. Move all light furniture as needed and return to original positions
|                                          | 
|Restroom Cleaning
Requirements            |  | Daily Services Five Days Per
Week       Dust and clean all restroom signage and doors.       Vacuum all restroom vestibules and remove spots.                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                       



101



---

|                                                   |  |                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                           
|-------------------------------------------------- |  | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
|                                                   |  |      Wet mop and disinfect tile floors, paying particular attention to
areas under urinals and toilet bowls.       Wash and disinfect all basin, urinals and toilet bowls. Clean underside rims of urinals and toilet bowls.                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                            
|                                                   | 
|                                                   |  |      Wash both sides of toilet seats with soap and water and disinfect.       Empty, clean, sanitize and polish all paper dispensers, replacing liners as
necessary.       Clean and polish all mirrors.       Dust ledges and baseboards.       Damp wipe, polish and shine all chrome, metal fixtures, hand plates, kick plates, utility
covers, plumbing, clean out covers and doorknobs.       Spot clean with disinfectant all partition and tile walls. (Report any graffiti and remove if possible).       Fill all soap, paper towel, toilet paper and sanitary napkin dispensers as
necessary.       Report all burned out lights, leaking faucets, running plumbing or other maintenance needs.  Semi-Weekly Services (2 Times per Week)       Pour clean water down floor drains to prevent sewer gasses from escaping.  Weekly Services       Wash down ceramic tile
floors and partitions inside and out and disinfect. (Report any graffiti and clean if possible).       Wash down all enamel walls.       Dust ledges and
baseboards.  Monthly Services       Scrub and wax tile
floors  Quarterly Services       Strip and wax tile
floors.
|                                                   | 
|Elevators Cleaning Requirements
(Where applicable) |  | Daily Services  Five Days Per Week      Vacuum and clean all spots and stains from carpet.       Dust and clean granite baseboards.       Dust and polish all
metal with approved polish (No abrasive).       Damp wipe and remove all spots and fingerprints from doors and walls. (Interior and Exterior).       Remove gum, stains or debris from ceilings, handrails and elevator tracks.       Clean all call buttons,
call plates, and signage.  Weekly Services       Clean and polish
elevator tracks.       Detail all call buttons and call plates. Dust and clean elevator ceilings and lights.       Disinfect and clean emergency phone and security compartments.                                                                                                                                                                                                                                                                                                                                                                                                                                                                                  



102



---

|                              |  |                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                        
|----------------------------- |  | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------
|Stairwells (Where
applicable) |  | Weekly       UncarpetedAll uncarpeted stairs and landing will be swept with a treated dust mop and
spot-cleaned as necessary to remove any spills, stains and litter.       Spot CleaningAll doors, jambs and walls will be spot-cleaned daily to remove all finger marks, smudges and stains.  Monthly       UncarpetedAll
uncarpeted stairs and landings will be wet-mopped and dried monthly.       DustingAll risers, handrails, stringers, baseboards, light fixture and all horizontal ledges and surfaces will be wiped with a treated dust cloth.  Quarterly       HighDustingAll high dusting, including, but not limited to, door closures and all other surfaces not reached by normal dusting operations will be dusted or cleaned, as necessary, but not less
often than each three (3) months.
|                              | 
|Day Porter Duties             |  | The Day Porter staff shall be trained and assigned to perform the following duties, and any additional project specific duties, as may be directed
by Management. Minimum duties to include:       Begin general policing of all restrooms. Restock supplies as needed. Report all items in need of repair to management. Restrooms to be checked at least twice daily.       Police Lobby interior
and exterior entrances to include cleaning of glass doors, frames, and entrance mats.       Police and maintain all passenger and freight elevators, if carpeted, elevators are to be
vacuumed and spot removed as required.       Clean corridors, utility areas and all designated smoking areas, as needed.       Set out rain mats, as needed.       Clean monument signs, as
required.                  
|                              | 
|Window Washing                |  | Bi-Annually (i.e., Two Times Per Year)       Clean interior windows.  Quarterly       Clean exterior windows.                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                                        



103