U.S. flag
          An official website of the United States Government  Main navigation
  

        

              Data Initiatives
                              Regulations
                                                                        Row 1
                                              FAR FAR
                              Smart Matrix Smart Matrix
                              Chapter 99 (CAS) Chapter 99 (CAS)
                              Row 2
                                              DFARS DFARS
                              DFARSPGI DFARSPGI
                              AFARS AFARS
                              DAFFARS DAFFARS
                              DAFFARS MP DAFFARS MP
                              DARS DARS
                              DLAD DLAD
                              NMCARS NMCARS
                              Row 3
                                              SOFARS SOFARS
                              TRANSFARS TRANSFARS
                              AGAR AGAR
                              AIDAR AIDAR
                              CAR CAR
                              DEAR DEAR
                              DIAR DIAR
                              DOLAR DOLAR
                              Row 4
                                              DOSAR DOSAR
                              DTAR DTAR
                              EDAR EDAR
                              EPAAR EPAAR
                              FEHBAR FEHBAR
                              GSAM/R GSAM/R
                              HHSAR HHSAR
                              HSAR HSAR
                              Row 5
                                              HUDAR HUDAR
                              IAAR IAAR
                              JAR JAR
                              LIFAR LIFAR
                              NFS NFS
                              NRCAR NRCAR
                              TAR TAR
                              VAAR VAAR
                              Tools
                                                                        Archives
                              Smart Matrix
                              Regulations Search
                              Acquisition Regulation Comparator (ARC)
                              Policy Network
                                                                        CAOC
                              CAAC
                              FAR Council
                              ISDC
 Breadcrumb
        Home
                            Regulations
                            NFS
                            1852.227-71   Requests for Waiver of Rights to Inventions.
        
                  HTML
NFSPart Number: 1852
        
                  

                                
                  
        NASA Federal Acquisition Regulation Supplement
« PreviousNext »
1852.227-71 Requests for Waiver of Rights to Inventions.1852.227-71 Requests for Waiver of Rights to Inventions.       As prescribed in 1827.303(d)(2), insert the following provision in all solicitations that include the clause at 1852.227–70, New Technology—Other than a Small Business Firm or Nonprofit Organization:                                  Requests for Waiver of Rights to Inventions (APR 2015)                                  (a) In accordance with Section 20135(g) of the National Aeronautics and Space Act (51 U.S.C. 20135(g)) (hereinafter “the Act”) and the NASA Patent Waiver Regulations, 14 CFR part 1245, subpart 1, NASA may waive all or any part of the rights of the United States with respect to any invention or class of inventions made or that may be made under a NASA contract or subcontract with other than a small business firm or a domestic nonprofit organization if the Administrator determines that the interests of the United States will be served thereby. Waiver of rights in inventions made or that may be made under such NASA contract or subcontract may be requested at different time periods. Advance waiver of rights to any invention or class of inventions that may be made under a contract or subcontract may be requested prior to the execution of the contract or subcontract, or within 30 days after execution by the selected contractor (or such longer period as may be specified by the Contracting Officer). In addition, waiver of rights to an individually identified invention or to a class of inventions made and reported under a contract or subcontract may be requested, even though a request for an advance waiver was not made or, if made, was not granted.                                  (b) Each request for waiver of rights shall be by petition to the Administrator. No specific forms need be used, but the request should contain a positive statement that waiver of rights is being requested under the NASA Patent Waiver Regulations; a clear indication of whether the request is for an advance waiver or for a waiver of rights for an individually identified invention or class of inventions; whether foreign rights are also requested and, if so, the countries, and a citation of the specific section or sections of the regulations under which such rights are requested. For individually identified inventions or a class of inventions, the petition shall identify each invention with particularity (*e.g.,* by NASA's assigned number to the Disclosure of Invention and New Technology report or by title and inventorship). For advance waivers, the petition shall identify the invention or class of inventions that the Contractor believes will be made under the contract and for which waiver is being requested. To meet the statutory standard of “any invention or class of inventions,” the petition must be directed to a single invention or to inventions directed to a particular process, machine, manufacture, or composition of matter, or to a narrowly-drawn, focused area of technology. Additionally, each petition shall include an identification of the petitioner; place of business and address; if petitioner is represented by counsel, the name, address and telephone number of the counsel; the name, address, and telephone number of the party with whom to communicate when the request is acted upon; the signature of the petitioner or authorized representative; and the date of signature. In general, waivers are granted in order to provide for the widest practicable dissemination of new technology resulting from NASA programs, and to promote early utilization, expeditious development, and continued availability of this new technology for commercial purposes and the public benefit. Thus, it is preferable that the petition also include a description of the Contractor's plan for commercializing the invention or class of inventions for which waiver is being requested (*e.g.,* identify specific fields of use).                                  (c) Petitions for advance waiver of rights should, preferably, be included with the proposal, or at least in advance of contract negotiations. Petitions for advance waiver, prior to contract execution, shall be submitted to the Contracting Officer. All other petitions shall be submitted to the Patent Representative designated in the contract.                                  (d) Petitions submitted with proposals selected for negotiation of a contract will be forwarded by the Contracting Officer to the installation Patent Counsel for processing and then to the Inventions and Contributions Board. The Board will consider these petitions and where the Board makes the findings to support the waiver, the Board will recommend to the Administrator that waiver be granted, and will notify the petitioner and the Contracting Officer of the Administrator's determination. The Contracting Officer will be informed by the Board whenever there is insufficient time or information or other reasons to permit a decision to be made without unduly delaying the execution of the contract. In the latter event, the petitioner will be so notified by the Contracting Officer. All other petitions will be processed by installation Patent Counsel and forwarded to the Board. The Board shall notify the petitioner of its action and if waiver is granted, the conditions, reservations, and obligations thereof will be included in the Instrument of Waiver. Whenever the Board notifies a petitioner of a recommendation adverse to, or different from, the waiver requested, the petitioner may request reconsideration under procedures set forth in the Regulations.                               (End of provision)    **Parent topic:**  Subpart 1852.2—Texts of Provisions and Clauses
« PreviousNext »
FavoriteX

      NFS Parts
            Regulations Nfs Menu
  

        
      Index
                              1800
                              1801
                              1803
                              1804
                              1805
                              1806
                              1807
                              1808
                              1809
                              1811
                              1812
                              1813
                              1814
                              1815
                              1816
                              1817
                              1819
                              1822
                              1823
                              1824
                              1825
                              1827
                              1828
                              1830
                              1831
                              1832
                              1833
                              1834
                              1835
                              1836
                              1837
                              1839
                              1840
                              1841
                              1842
                              1843
                              1844
                              1845
                              1846
                              1847
                              1849
                              1850
                              1851
                              1852
                              1853
                              18721899

      ×
        Data Initiatives
                                                              Regulations
                                                              Tools
                                              Archives
                                                              Smart Matrix
                                                              Regulations Search
                                                              Acquisition Regulation Comparator (ARC)
                                                              Policy Network
                                              CAO.gov
                                                        CAO Home
                                                              Council Member
                                                                    Large Agencies
                                                              Small Agencies
                                                              Council Defining Documents
                                                                    CAOC History
                                                              CAOC Charter
                                                              Civilian Agency Acquisition Council (CAAC)
                                                              Federal Acquisition Regulatory Council
                                                              Interagency Suspension and Debarment Committee (ISDC)
                                                              Search
 ˄ Top Sign up for FAR News

                            Share the FAR
                        Upper Footer Menu
  

        
      Useful Links
                              FAR Resources
                              Training
                              Acquisition Systems
            
                            **Contact Us/FAQs**
                        **Privacy and Security Notice**
                        **Accessibility Aids**
                        **Last Updated 03/29/2024**
 ACQUISITION.GOV
                An official website of the General Services Administration About GSA
                Accessibility support
                FOIA requests
                No FEAR Act data
                Office of the Inspector General
                Performance reports
                Privacy policy Looking for U.S. government information and services?
            Visit USA.gov
 «
    
    Tt