U.S. flag
          An official website of the United States Government  Main navigation
  

        

              Data Initiatives
                              Regulations
                                                                        Row 1
                                              FAR FAR
                              Smart Matrix Smart Matrix
                              Chapter 99 (CAS) Chapter 99 (CAS)
                              Row 2
                                              DFARS DFARS
                              DFARSPGI DFARSPGI
                              AFARS AFARS
                              DAFFARS DAFFARS
                              DAFFARS MP DAFFARS MP
                              DARS DARS
                              DLAD DLAD
                              NMCARS NMCARS
                              Row 3
                                              SOFARS SOFARS
                              TRANSFARS TRANSFARS
                              AGAR AGAR
                              AIDAR AIDAR
                              CAR CAR
                              DEAR DEAR
                              DIAR DIAR
                              DOLAR DOLAR
                              Row 4
                                              DOSAR DOSAR
                              DTAR DTAR
                              EDAR EDAR
                              EPAAR EPAAR
                              FEHBAR FEHBAR
                              GSAM/R GSAM/R
                              HHSAR HHSAR
                              HSAR HSAR
                              Row 5
                                              HUDAR HUDAR
                              IAAR IAAR
                              JAR JAR
                              LIFAR LIFAR
                              NFS NFS
                              NRCAR NRCAR
                              TAR TAR
                              VAAR VAAR
                              Tools
                                                                        Archives
                              Smart Matrix
                              Regulations Search
                              Acquisition Regulation Comparator (ARC)
                              Policy Network
                                                                        CAOC
                              CAAC
                              FAR Council
                              ISDC
 Breadcrumb
        Home
                            Regulations
                            FAR
                            Subpart 11.5 - Liquidated Damages
        
                  FAR
FAR
FAC Number: 2024-03 Effective Date: 02/23/2024
PartPart 1Part 2Part 3Part 4Part 5Part 6Part 7Part 8Part 9Part 10Part 11Part 12Part 13Part 14Part 15Part 16Part 17Part 18Part 19Part 20Part 21Part 22Part 23Part 24Part 25Part 26Part 27Part 28Part 29Part 30Part 31Part 32Part 33Part 34Part 35Part 36Part 37Part 38Part 39Part 40Part 41Part 42Part 43Part 44Part 45Part 46Part 47Part 48Part 49Part 50Part 51Part 52Part 53
Subpart11.011.111.211.311.411.511.611.711.8
Section11.50011.50111.50211.503
Leave this field blank
        
                  

                                
                  
        « PreviousNext »
Subpart 11.5 - Liquidated DamagesSubpart 11.5 - Liquidated Damages    **Parent topic:**  Part 11 - Describing Agency Needs11.500 Scope.       (a)                    						            This subpart prescribes policies and procedures for using liquidated damages clauses in solicitations and contracts for supplies, services, research and development, and construction.                                          (b)                    						            This subpart does not apply to liquidated damages-                                                         (1)                          								                For subcontracting plans (see  19.705-7);                                                            (2)                          								                Related to the Contract Work Hours and Safety Standards statute (see  subpart  22.3); or                                                            (3)                          								                Related to paid sick leave for Federal contractors (see  subpart  22.21).11.501 Policy.       (a)                    						            The contracting officer must consider the potential impact on pricing, competition, and contract administration before using a liquidated damages clause. Use liquidated damages clauses only when-                                                         (1)                          								                The time of delivery or timely performance is so important that the Government may reasonably expect to suffer damage if the delivery or performance is delinquent; and                                                            (2)                          								                The extent or amount of such damage would be difficult or impossible to estimate accurately or prove.                                                                             (b)                    						            Liquidated damages are not punitive and are not negative performance incentives (see  16.402-2). Liquidated damages are used to compensate the Government for probable damages. Therefore, the liquidated damages rate must be a reasonable forecast of just compensation for the harm that is caused by late delivery or untimely performance of the particular contract. Use a maximum amount or a maximum period for assessing liquidated damages if these limits reflect the maximum probable damage to the Government. Also, the contracting officer may use more than one liquidated damages rate when the contracting officer expects the probable damage to the Government to change over the contract period of performance.                                          (c)                    						            The contracting officer must take all reasonable steps to mitigate liquidated damages. If the contract contains a liquidated damages clause and the contracting officer is considering terminating the contract for default, the contracting officer should seek expeditiously to obtain performance by the contractor or terminate the contract and repurchase (see  subpart  49.4). Prompt contracting officer action will prevent excessive loss to defaulting contractors and protect the interests of the Government.                                          (d)                    						            The head of the agency may reduce or waive the amount of liquidated damages assessed under a contract, if the Commissioner, Financial Management Service, or designee approves (see Treasury Order 145-10).11.502 Procedures.       (a)                    						            Include the applicable liquidated damages clause and liquidated damages rates in solicitations when the contract will contain liquidated damages provisions.                                          (b)                    						            Construction contracts with liquidated damages provisions must describe the rate(s) of liquidated damages assessed per day of delay. The rate(s) should include the estimated daily cost of Government inspection and superintendence. The rate(s) should also include an amount for other expected expenses associated with delayed completion such as-                                                         (1)                          								                Renting substitute property; or                                                            (2)                          								                Paying additional allowance for living quarters.11.503 Contract clauses.       (a)                    						            Use the clause at  52.211-11, Liquidated Damages-Supplies, Services, or Research and Development, in fixed-price solicitations and contracts for supplies, services, or research and development when the contracting officer determines that liquidated damages are appropriate (see  11.501(a)).                                          (b)                    						            Use the clause at  52.211-12, Liquidated Damages-Construction, in solicitations and contracts for construction, other than cost-plus-fixed-fee, when the contracting officer determines that liquidated damages are appropriate (see  11.501(a)). If the contract specifies more than one completion date for separate parts or stages of the work, revise paragraph (a) of the clause to state the amount of liquidated damages for delay of each separate part or stage of the work.                                          (c)                    						            Use the clause at  52.211-13, Time Extensions, in solicitations and contracts for construction that use the clause at  52.211-12, Liquidated Damages-Construction, when that clause has been revised as provided in paragraph (b) of this section.
« PreviousNext »
FavoriteX

      Far Parts
            Regulations FAR Menu
  

        
      Index
                              List of Sections Affected
                              DOD Deviations
                              CAAC Deviations
                              1
                              2
                              3
                              4
                              5
                              6
                              7
                              8
                              9
                              10
                              11
                              12
                              13
                              14
                              15
                              16
                              17
                              18
                              19
                              20
                              21
                              22
                              23
                              24
                              25
                              26
                              27
                              28
                              29
                              30
                              31
                              32
                              33
                              34
                              35
                              36
                              37
                              38
                              39
                              40
                              41
                              42
                              43
                              44
                              45
                              46
                              47
                              48
                              49
                              50
                              51
                              52
                              53
                              Chapter 99 (CAS)Definitions
    Toggle
FAC Changes
    Toggle
Style Formatter
    Toggle

      ×
        Data Initiatives
                                                              Regulations
                                                              Tools
                                              Archives
                                                              Smart Matrix
                                                              Regulations Search
                                                              Acquisition Regulation Comparator (ARC)
                                                              Policy Network
                                              CAO.gov
                                                        CAO Home
                                                              Council Member
                                                                    Large Agencies
                                                              Small Agencies
                                                              Council Defining Documents
                                                                    CAOC History
                                                              CAOC Charter
                                                              Civilian Agency Acquisition Council (CAAC)
                                                              Federal Acquisition Regulatory Council
                                                              Interagency Suspension and Debarment Committee (ISDC)
                                                              Search
 ˄ Top Sign up for FAR News

                            Share the FAR
                        Upper Footer Menu
  

        
      Useful Links
                              FAR Resources
                              Training
                              Acquisition Systems
            
                            **Contact Us/FAQs**
                        **Privacy and Security Notice**
                        **Accessibility Aids**
                        **Last Updated 03/29/2024**
 ACQUISITION.GOV
                An official website of the General Services Administration About GSA
                Accessibility support
                FOIA requests
                No FEAR Act data
                Office of the Inspector General
                Performance reports
                Privacy policy Looking for U.S. government information and services?
            Visit USA.gov
 «
    
    Tt