I 

118TH CONGRESS 

1ST SESSION H. R. 1180 

To require the Director of the Office of Management and Budget to submit 

to Congress an annual report on projects that are over budget and 

behind schedule, and for other purposes. 

IN THE HOUSE OF REPRESENTATIVES 

FEBRUARY 24, 2023 

Mr. GALLAGHER (for himself and Ms. PORTER) introduced the following bill; 

which was referred to the Committee on Oversight and Accountability, 

and in addition to the Committee on Armed Services, for a period to be 

subsequently determined by the Speaker, in each case for consideration 

of such provisions as fall within the jurisdiction of the committee concerned 

A BILL 

To require the Director of the Office of Management and 

Budget to submit to Congress an annual report on 

projects that are over budget and behind schedule, and 

for other purposes. 

1 Be it enacted by the Senate and House of Representa2 tives of the United States of America in Congress assembled, 

3 SECTION 1. SHORT TITLE. 

4 This Act may be cited as the ‘‘Billion Dollar Boon5 doggle Act of 2023’’. 


kjohnson on DSK79L0C42PROD with BILLS
2 

•HR 1180 IH

1 SEC. 2. ANNUAL REPORT. 

2 (a) DEFINITIONS.—In this section— 

3 (1) the term ‘‘covered agency’’ means— 

4 (A) an Executive agency, as defined in sec5 tion 105 of title 5, United States Code; and 

6 (B) an independent regulatory agency, as 

7 defined in section 3502 of title 44, United 

8 States Code; 

9 (2) the term ‘‘covered project’’ means a project 

10 funded by a covered agency— 

11 (A) that is more than 5 years behind 

12 schedule; or 

13 (B) for which the amount spent on the 

14 project is not less than $1,000,000,000 more 

15 than the original cost estimate for the project; 

16 and 

17 (3) the term ‘‘project’’ means a major acquisi18 tion, a major defense acquisition program (as de19 fined in section 2430 of title 10, United States 

20 Code), a procurement, a construction project, a re21 mediation or clean-up effort, or any other time-lim22 ited endeavor, that is not funded through direct 

23 spending (as defined in section 250(c) of the Bal24 anced Budget and Emergency Deficit Control Act of 

25 1985 (2 U.S.C. 900(c)). 


kjohnson on DSK79L0C42PROD with BILLS
3 

•HR 1180 IH

1 (b) REQUIREMENT.—Not later than 1 year after the 

2 date of enactment of this Act, the Director of the Office 

3 of Management and Budget shall issue guidance requiring 

4 covered agencies to include, on an annual basis in a report 

5 described in paragraph (2) of section 3516(a) of title 31, 

6 United States Code, or a consolidated report described in 

7 paragraph (1) of such section, information relating to each 

8 covered project of the covered agency, which shall in9 clude— 

10 (1) a brief description of the covered project, 

11 including— 

12 (A) the purpose of the covered project; 

13 (B) each location in which the covered 

14 project is carried out; 

15 (C) the contract or award number of the 

16 covered project, where applicable; 

17 (D) the year in which the covered project 

18 was initiated; 

19 (E) the Federal share of the total cost of 

20 the covered project; and 

21 (F) each primary contractor, subcon22 tractor, grant recipient, and subgrantee recipi23 ent of the covered project; 

24 (2) an explanation of any change to the original 

25 scope of the covered project, including by the addiVerDate Sep 11 2014 00:40 Mar 12, 2023 Jkt 039200 PO 00000 Frm 00003 Fmt 6652 Sfmt 6201 E:\BILLS\H1180.IH H1180

kjohnson on DSK79L0C42PROD with BILLS
4 

•HR 1180 IH

1 tion or narrowing of the initial requirements of the 

2 covered project; 

3 (3) the original expected date for completion of 

4 the covered project; 

5 (4) the current expected date for completion of 

6 the covered project; 

7 (5) the original cost estimate for the covered 

8 project, as adjusted to reflect increases in the Con9 sumer Price Index for All Urban Consumers, as 

10 published by the Bureau of Labor Statistics; 

11 (6) the current cost estimate for the covered 

12 project, as adjusted to reflect increases in the Con13 sumer Price Index for All Urban Consumers, as 

14 published by the Bureau of Labor Statistics; 

15 (7) an explanation for a delay in completion or 

16 an increase in the original cost estimate for the cov17 ered project, including, where applicable, any impact 

18 of insufficient or delayed appropriations; and 

19 (8) the amount of and rationale for any award, 

20 incentive fee, or other type of bonus, if any, awarded 

21 for the covered project. 

Æ 


kjohnson on DSK79L0C42PROD with BILLS