The Mt. Juliet Planning Commission was later added as a defendant.

1

IN THE COURT OF APPEALS OF TENNESSEE

AT NASHVILLE

October 9, 2003 Session

STS/BAC JOINT VENTURE v. THE CITY OF MT. JULIET, 

TENNESSEE ET AL.

Appeal from the Chancery Court for Wilson County

No. 99205 Charles K. Smith, Chancellor

No. M2003-00171-COA-R3-CV - Filed December 1, 2004

The developer of a planned Wilson County subdivision sought damages for a temporary taking,

claiming that the City of Mt. Juliet interfered with the completion of the project by arbitrarily

refusing to grant necessary permits. The trial court granted summary judgment to Mt. Juliet, in part

on the ground that the statute of limitations had passed on the developer’s claim for relief. We

affirm.

Tenn. R. App. P. 3 Appeal as of Right; Judgment of the Chancery Court Affirmed

PATRICIA J.COTTRELL,J., delivered the opinion ofthe court, in which WILLIAM B.CAIN, and FRANK

G. CLEMENT JR., JJ., joined.

George A. Dean, Nashville, Tennessee, for the appellant, STS/BAC Joint Venture.

John E. Quinn, Douglas B. Janney III, Nashville, Tennessee, for the appellees, TheCityof Mt. Juliet,

Tennessee and the Mt. Juliet Planning Commission.

OPINION

This case began when the developer of a subdivision filed a complaint on May 26, 1999,

against the city of Mt. Juliet alleging, inter alia, that the city, through its planning commission, had 1

arbitrarily and illegally denied approvals for further development of the project, thereby depriving

the developer of beneficial use of his property in violation of the takings clauses of both the United

States Constitution and the Tennessee Constitution. The developer alleged that from late 1995 or

early 1996, the city either denied applications for permits or delayed action on such applications. 
The relevant facts are taken from filings made in support of and opposition to dispositive motions filed by all 2

parties at various times.

The City Manager’s affidavit stated that his letter referred only to the Wilson County zoning regulations, not

3

to all of Wilson County’s land use regulations. 

-2-

The case was eventually dismissed by final order granting the city’s motion for summary

judgment and the commission’s motion to dismiss. In that order the trial court held, “Specifically,

the Court finds that Plaintiff’s claims against Defendants are barred by the statute of limitations and

applicable law.”

I. A PLANNED SUBDIVISION

The property in dispute is a 240-250 acre tract of land in Wilson County which Nashville

Land Partners acquired for the purpose of creating a large residential development to be completed

in phases. The plan was to divide the property, called the Park Glen subdivision, into 740 separate 2

lots, to be serviced by a new infrastructure of roads and utilities. A preliminary subdivision plan was

presented to the Wilson County Planning Commission and approved on May 14, 1987.

At the time of the approval and thereafter, Wilson County had a subdivision regulation that

stated, “approval of the preliminary plat shall lapse unless a final plat based thereon is submitted

within one-year from the date of such approval. . . .” Another regulation in effect made it clear that

“approval of the preliminary plat by the Planning Commission shall not constitute acceptance of the

final plat.”

Nashville Land Partners asked the City of Mt. Juliet to extend its sanitary sewer system to

Park Glen. On July 13, 1987, Nashville Land Partners and the Mt. Juliet Sewer Board signed an

agreement allocating the costs and obligations of the sewer extensions between the parties. The

owner also urged the City of Mt. Juliet to annex the subdivision property. On November 10, 1987,

Danny Farmer, Mt Juliet’s City Manager wrote a brief letter to Nashville Land Partners that read:

The policy of the City of Mt. Juliet, in regard to the annexation of the above

referenced subdivision into the city, is that it will be allowed to conform to the

current Wilson County zoning since the preliminary plot (sic) has been approved by

the Wilson County Planning Commission and work has commenced on the project.

The legal effect ofthat letter became a point of contention between the parties. In November 3

of 1987, the subdivision property was annexed by the city, transferring authority over the subdivision

to the Mt. Juliet Planning Commission. At the time of the annexation, Mt. Juliet, like Wilson

County, had a subdivision regulation providing that if a final plat for a subdivision that has received

preliminary approval is not submitted within twelve months of the preliminary plat approval, then

the preliminary plat is null and void and must be resubmitted for preliminary approval again. A final

plat was submitted to the Wilson County Planning Commission, but was denied by that commission
The members of the joint venture are the Nashville Corporation, Inc. and an individual named Brent Campbell. 4

Apparently STS/BAC initially took the position it had only purchased lots, not the development, which was

5

relevant to responsibility for infrastructure.

-3-

on November 12, 1987. Within one year of the May 1987 approval of Park Glen’s preliminary plat,

Nashville Land Partners submitted a final plat for some phases or sections of the subdivision, and

approval for those plats was granted by the Mt. Juliet Planning Commission since annexation had

occurred. Much of the subdivision was not covered by these final plats. No final plat for the

remainder of the subdivision was ever submitted to the Mt. Juliet Planning Commission by Nashville

Land Partners.

Nashville Land Partners defaulted on its obligations, and its lender was placed into

receivership, with the Federal Deposit Insurance Corporation seizing its assets in 1991. A joint

venture called STS/BAC (“developer”) purchased the disputed property in a December 1993 4

foreclosure sale. By that time, the property consisted of 47 platted and developed lots in Sections 5

1, 2, and 3 of the subdivision, and additional unplatted acreage.

At some point after the purchase, STS/BAC began efforts to develop more of Park Glen. By

letter dated March 31, 1995, the city informed STS/BAC that the commission had not approved a

preliminary plan for Phase II, Sections 1 and 2 of Park Glen Subdivision. The letter continued,

“Based on your discussion with the Commission on March 16, 1995, a new preliminary plan must

be submitted and approved by the Planning Commission.”

The developer placed on the agenda for the April 1995 commission meeting the original 1987

preliminary plat for Park Glen subdivision for preliminary approval, but withdrew it after staff

indicated it would recommend against approval because of noncompliance with commission

requirements regarding a concept plan.

In May of 1995, STS/BAC submitted for preliminary approval a section of the Park Glen

subdivision (Lots 82-132 in Section 3). Preliminary approval was granted by the commission and

on November 30, 1995, final approval for specified lots covered by that preliminary plat was granted.

Prior to the commission’s June 27, 1996, meeting, the developer requested approval of a

concept plan, but did not submit a preliminary plat for the subdivision. The next activity reflected

in the record was a commission meeting on January 15, 1998, wherein the developer told the

commission it was the developer’s position that no new preliminary subdivision plat had to be

submitted for approval because of the 1987 approval by the Wilson County Planning Commission.

Based upon an opinion from counsel, the city engineer again took the position that the approval

granted by the Wilson County Planning Commission had lapsed one year later. The commission

continued to adhere to its interpretation of the regulation, to conclude there was no valid preliminary

plat, and to require that the developer submit a new preliminary plat for the subdivision as a whole.
As a consequence, some of the claims and requests for relief included in the complaint were rendered moot,

6

leaving only the takings claim at issue. SCA Chemical Waste Services, Inc. v. Konigsberg, 636 S.W.2d 430 (Tenn. 1982)

(holding that where clean air permit was issued after appeal perfected, the action was moot as to request for order to issue

permit).

Government action that denies a landowner all use of his property for a period of time, if such action is 7

determined to be a taking, is compensable. First English Evangelical Church of Glendale v. Co. Los Angeles, 482 U.S.

304, 304, 107 S. Ct. 2378, 2388 (1987) (holding “where the government’s actions have already worked a taking of all

use of property, no subsequent action by the government can relieve it of the duty to provide compensation for the period

during which the taking was effective.”)

-4-

The minutes of the July 16, 1998 meeting of the Commission reflect that the developer

appeared and stated he had submitted a preliminary plat for another section of Park Glen and

requested it be placed on the agenda. Again, Commission staff reiterated its position that the

developer must submit an preliminary plat for the subdivision as a whole as a prerequisite to any

further development of Park Glen. The developer again argued that the 1987 approval of the

preliminary plat was still effective and no new preliminary plat was required.

According to affidavits dated August of 2000, at that point there had been no other efforts

by the developer to obtain commission approval for further development of the subdivision. No

preliminary plat for the subdivision as a whole had been submitted. The subdivision had been

developed to the extent permitted by approved and recorded plats.

When the developer filed this action in May of 1999, it alleged that after late 1995 or early

1996, construction on the development came to a halt because the developer was unable to obtain

necessary approval for additional plans and permits from the Mt. Juliet Regional Planning

Commission. While the litigation was pending, approvals for further development were given in

2001. At the time of the final judgment, the only issue before the trial court was whether the 6

developer’s claims to compensatory damages for a temporary taking of its property prior to 2001 7

should be dismissed on substantive or statute of limitations grounds.

II. THE LAW OF GOVERNMENTAL TAKINGS

The developer’s complaint was brought pursuant to 42 U.S.C. § 1983 and characterized Mt.

Juliet’s refusal to grant the requested permits as arbitrary and capricious actions that worked a taking

(a temporary taking in view of eventual approval) of the developer’s property without just

compensation, in violation of the both the Tennessee and United States Constitutions. The

complaint sought $ 2 million in compensatory damages and attorneys’ fees in accordance with 42

U.S.C. § 1988. Because the trial court dismissed the complaint under either, or both, applicable

substantive law and statute of limitations grounds, some discussion of the law of regulatory takings

is necessary.

The second clause of the Fifth Amendment to the United States Constitution, called the

Takings Clause or the Just Compensation Clause, provides “nor shall private property be taken for
-5-

public use, without just compensation.” This clause is predicated on the proposition that the

government should pay for private property it has taken for its own use. Its purpose is to prevent the

government from forcing an individual or group of individuals alone to bear burdens “which, in all

fairness and justice, should be borne by the public as a whole.” Palazzolo v. Rhode Island, 533 U.S.

606, 618, 121 S. Ct. 2448, 2457-58 (2001); Dolan v. City of Tigard, 512 U.S. 374, 384 (1994);

Armstrong v. United States, 364 U.S. 40, 49, 80 S. Ct. 1563 (1960). 

The Takings Clause oftheUnited States Constitution was generally understood to apply only

to physical takings until the United States Supreme Court held in Pennsylvania Coal Co. v. Mahon,

260 U.S. 393, 415, 43 S. Ct. 158 (1922) that “while property may be regulated to a certain extent,

if regulation goes too far it will be recognized as a taking.” The Court did not then, and has not

since, established a formula for determining when regulation “goes too far.” Tahoe-Sierra

Preservation Council, Inc. v. Tahoe Regional Planning Agency, 535 U.S. 302, 326-37, 122 S. Ct.

1465, 1481 (2002). Instead, the Court has consistently held that in cases involving regulatory

takings, examination of multiple factors is necessary. Id. Where the allegation is one of regulatory

taking, neither public use nor physical appropriation of the land is required. Id., 535 U.S. at 326, 122

S. Ct. at 1481.

The one exception to the general balancing of factors approach is where a governmental

regulatory action permanently eliminates all economic value from an entire piece of property by

prohibiting all economically beneficial use. In that situation, a “per se” taking has occurred, and

“total regulatory takings” must be compensated unless the government can show that the proscribed

uses were not part of the owner’s interests under state property and nuisance law. Tahoe-Sierra

Preservation Council, 535 U.S. at 324 n.19, 332, 122 S. Ct. at 1479 n.19, 1484; Lucas v. South

Carolina Coastal Council, 505 U.S. 1003, 1019, 112 S. Ct. 2886, 2895 (1992) (holding “when the

owner of real property has been called upon to sacrifice all economically beneficial uses in the name

of the common good, that is, to leave his property economically idle, he has suffered a taking.”) 

Absent a total taking, the analysis established in Penn Cent. Transp. Co. v. New York City,

438 U. S. 104, 98 S. Ct. 2646 (1978), will be applied in a fact specific inquiry. Tahoe-Sierra

Preservation Council, 535 U.S. at 332, 342, 122 S. Ct. at 1484, 1489 (holding that the question of

whether a 32-month moratorium on development while mandated land-use policies were adopted

constituted a taking was not to be answered by any categorical rule, but, instead, by reliance on the

familiar Penn Central approach); Palazzolo, 533 U.S. at 617, 121 S. Ct. at 2457. Where government

regulation does not represent a total taking, such a case “necessarily entails complex factual

assessments of the purposes and economic effects of government action.” Brown v. Legal

Foundation of Washington, 538 U.S. 216, 234, 123 S. Ct. 1406, 1418 (2003); Tahoe-Sierra

Preservation Council, 535 U.S. at 323, 122 S. Ct. at 1465; Yee v. Escondido, 503 U.S. 519, 523, 112

S. Ct. 1522 (1992). 

Under Penn Central, regulatory takings claims require “ad hoc, factual inquiries” involving

a balancing of the public and private interests involved in the particular case. The factors to be

considered include (1) the economic impact of the regulation, (2) the degree to which the regulation
-6-

has interfered with the owner’s reasonable “distinct investment-backed” expectations concerning the

property, and (3) the character of the regulatory action. Penn Central, 438 U.S. at 124-25; 98 S. Ct.

2646. Other relevant factors may also be considered. The analysis, however, must focus on “the

parcel as a whole.” Tahoe-Sierra Preservation Council, 535 U.S. at 326-27, 122 S. Ct. at 1481;

Penn Central, 438 U.S. at 130-131, 98 S. Ct. 2646. “[W]here an owner possesses a full ‘bundle’ of

rights, the destruction of one ‘strand’ of the bundle is not a taking.” Tahoe-Sierra Preservation

Council, 535 U.S. at 327, 122 S. Ct. at 1481, quoting Andrus v. Allard, 444 U.S. 51, 65-66, 100 S.

Ct. 318 (1979).

Thus, the Supreme Court’s regulatory takings jurisprudence “is characterized by ‘essentially

ad hoc, factual inquiries,’ designed to allow ‘careful examination and weighing of all the relevant

circumstances.’” Legal Foundation of Washington, 538 U.S. at 233, 123 S. Ct. at 1417-18; TahoeSierra Preservation Council, 535 U.S. at 323, 122 S. Ct. at 1465, quoting Palazzolo, 533 U.S. at

636, 121 S. Ct. at 2467 (O’Connor, J., concurring). 

Additionally, even when something less than all economicallyviable use has been destroyed,

or when the owner has not been denied all economically viable use of his land, government

regulation may still constitute a taking if such regulation “does not substantially advance legitimate

state interests.” City of Monterey v. Del Monte Dunes at Monterey, Ltd., 526 U.S. 687, 704, 119 S.

Ct. 1624, 1636 (1999); Agins v. Tiburon, 447 U.S. 255, 260 (1980); Dodd v. Hood River County, 136

F.3d 1219, 1228 (9th Cir. 1998). Thus, land use regulation can effect a taking if such regulation does

not substantially advance legitimate state interests or denies an owner economically viable use of his

land. Keystone Bituminous Coal Assoc. v. De Benedictis, 480 U.S. 470, 485, 107 S. Ct. 1232 (1987)

(reaffirming the Agins test).

Almost all of the Supreme Court’s holdings on regulatory takings involve the adoption of

ordinances, regulations, or other legislation that limit development or regulate land use. However,

in at least one case the Court has found that other governmental regulatory activity constituted a

taking. In Del Monte Dunes, 526 U.S. at 687, 119 S. Ct. at 1624, the Court considered actions by

a local government, taken over five years, denying landowners permission to develop their property.

In that case, the landowners submitted their initial plan in 1981 in conformance with existing

zoning and general planning requirements, proposing substantially fewer units than existing

requirements would allow. The planning commission denied the application, but suggested that a

proposal for a specified smaller number of units would receive favorable consideration. When the

landowners submitted a revised proposal meeting those suggestions, the commission again denied

the application and suggested an even greater reduction in the scale of the development, again stating

a specific number of units. The landowners tried again, submitting a revised plan for the number of

units suggested. The commission again denied the application. The landowners appealed to the city

council, which overruled the commission and referred the plan back to the commission with

instructions to consider a proposal for even fewer units.
-7-

The landowners once again reduced the number of units to be included in the development

to comply with the council’s instructions and submitted four specific, detailed site plans. The

commission, nonetheless, again rejected the proposal. The city council again overruled the

commission, “finding the proposal conceptually satisfactory and in conformance with the city’s

previous decisions regarding, inter alia, density, number of units, location on the property, and

access.” 526 U.S. at 696, 119 S. Ct. at 1632. The council approved one of the site plans, subject to

specific conditions, and granted an 18-month conditional use permit for the development.

The landowners submitted a final plan addressing all the conditions specified by the city.

The city’s architectural review committee approved the plan, and the staff of the planning

commission recommended approval of the plan as satisfying the city’s conditions. The commission

rejected the recommendation of its staff and denied approval of the development plan. The

landowners again appealed to the city council which denied the final plan, declined to specify what

other measures the landowners could take, and refused to extend the conditional use permit. The

Supreme Court stated that the council did not base its decision on the landowners’ failure to meet

any of the specific conditions earlier required by the city, but made general findings as to the plan’s

inadequacies that were unsupported by the facts. 

The jury found there was a taking based on jury instructions that it should find for the

landowners if it found either that the landowners had been denied all economically viable use of its

property or that the city’s rejection of the plaintiff’s development proposal did not substantially

advance a legitimate public purpose. 526 U.S. at 700, 119 S. Ct. at 1634. There was sufficient

evidence for the jury to conclude that the city’s purported reasons for denying the development

application were invalid and that the city unfairly intended to forestall any reasonable development

of the property. 526 U.S. at 703, 119 S. Ct. at 1635. 

The city’s actions in Del Monte Dunes were described as shifting in the nature of the

demands made and its final denial as inconsistent with its professional staff and its own previous

decisions. 526 U.S. at 706, 119 S. Ct. at 1637. There was also proof that the city had long been

interested in acquiring the property itself. Id.

In Del Monte Dunes the Court carefully distinguished the city’s conduct in that case from

other “routine regulatory decisions.” 526 U.S. at 706-07; 119 S. Ct. at 1637. See also Tahoe-Sierra

Preservation Council, 535 U.S. at 334, 122 S. Ct. at 1485 (distinguishing the diligent and good faith

efforts of the board in that case from the “stalling” in Del Monte Dunes). Further, in Palazzolo, the

Court cited Del Monte Dunes for the statement that, “Government authorities, of course, may not

burden property by imposition of repetitive or unfair land-use procedures in order to avoid a final

decision.” 533 U.S. at 621, 121 S. Ct. at 2460. 

In fact, the Court has recognized that different questions arise “in the case of normal delays

in obtaining building permits, changes in zoning ordinances, variances, and the like. . . .” See TahoeSierra Preservation Council, 535 U.S. at 329, 122 S. Ct. at 1482; First English Evangelical Church,

482 U.S. at 321, 107 S. Ct. at 2378. The Court has long recognized the police power of local
-8-

governments and has stated that such governments “may, consistent with the Takings Clause, affect

property values by regulation without incurring an obligation to compensate - - a reality [the Court]

acknowledge[s] explicitly with respect to the full scope of the State’s police power.” Lucas, 505

U.S. at 1023, 112 S. Ct. at 2897. 

The developer has not alleged a total regulatory taking, and cannot make such an allegation

in view of the temporary nature of the denial of permits. Further, the developer has not shown that

development or all economic use of the property was prevented. Although the developer has alleged

that the refusal to grant further permits was arbitrary, it has not specifically alleged that the

Commission’s decision did not substantially advance governmental interests. The developer has not

specifically refuted the Commission’s proof that its denials were based on its interpretation of its

regulations regarding the lapse of a preliminary plan after one year and the developer’s refusal to

submit a new preliminary plan. These facts certainly distinguish the Commission’s acts here from

those of the city in the Del Monte Dunes case. In addition, they are relevant to the developer’s claim

of arbitrariness and to any question of legitimate governmental interests. 

While we have serious doubts about the developer’s ability to establish the elements

necessary to a compensable temporary taking, we nonetheless decline to decide that Mt. Juliet is

entitled to judgment as a matter of substantive takings law based on the record before us.

Additionally, we believe it is more likely the trial court’s dismissal was based upon the city’s statute

of limitations argument. From their briefs, the parties share that interpretation. 

III. STATUTE OF LIMITATIONS

There is another requirement of takings law that is relevant to our discussion of the applicable

statute of limitations. A taking of property for public use violates the Takings Clause only if just

compensation is not paid. “The Fifth Amendment does not proscribe the taking of property, it

proscribes taking without compensation.” Williamson County Regional Planning Commission v.

Hamilton Bank of Johnson City, 473 U.S. 172, 194, 105 S. Ct. 3108, 3120 (1985). If no

compensation is due, there is no constitutional violation. Legal Foundation of Washington, 538 U.S.

at 240, 123 S. Ct. at 1421. 

Similarly, there is no constitutional violation if the government provides an adequate

postdeprivation remedy for the property loss and just compensation is received. Del Monte Dunes,

526 U.S. at 714-15, 119 S. Ct. at 1641.

The Fifth Amendment does not proscribe the taking of property; it proscribes taking

without just compensation. Nor does the Fifth Amendment require that just

compensation be paid in advance of or contemporaneously with, the taking; all that

is required is that a ‘reasonable, certain and adequate provision for obtaining

compensation’ exist at the time of the taking. If the government has provided an

adequate process for obtaining compensation, and if resort to that process ‘yield[s]

just compensation,’ then the property owner ‘has no claim against the Government”
The Tennessee Constitution in Article I, Section 8 provides that “no man shall be . . . deprived of his life,

8

liberty, or property, but by the judgment of his peers or the law of the land.” Article I, Section 21 provides that “no

man’s particular services shall be demanded, or property taken, or applied to public use, without the consent of his

representatives or without just compensation being made therefor.” These provisions apply to governmental taking of

property. Barge v. Sadler, 70 S.W.3d 683, 687 n.4 (Tenn. 2002); Far Tower Sites, LLC v. Knox Co., 126 S.W.3d 52,

62-63 (Tenn. Ct. App. 2003); Cross v. McCurry, 859 S.W.2d 349, 353 (Tenn. Ct. App. 1993).

The same view is taken of the Takings Clause of the United States Constitution: it affirms the government’s 9

authority to confiscate private property, but imposes two conditions: the taking must be for a public use, and just

compensation must be paid. Legal Foundation of Washington, 538 U.S. at 231-32, 123 S. Ct. at 1417.

-9-

for a taking. Thus, we have held that taking claims against the Federal Government

are premature until the property owner has availed itself of the process provided by

the Tucker Act, 28 U.S.C. § 1491. Similarly, if a State provides an adequate

procedure for seeking just compensation, the property owner cannot claim a violation

of the Just Compensation Clause until it has used the procedure and been denied just

compensation.

Williamson County, 473 U.S. at 195, 105 S. Ct. at 3120-21 (citations omitted). The requirement that

a landowner pursue state remedies for just compensation before bringing a claim based on violation

of the Fifth Amendment is a ripeness requirement applicable to federal courts. Id. However, the

Supreme Court’s discussion of Tennessee procedures for seeking compensation for a regulatory

taking is instructive, along with Tennessee holdings, in determining the appropriate statute of

limitations.

In Williamson County, the Court found that the plaintiff’s claim was not ripe for review

because it had not sought just compensation pursuant to Tennessee law. The Court found that

Tennessee’s inverse condemnation statutes and procedures allowed recovery for a taking, including

one “effected by restrictive zoning laws or development regulations,” i.e., a regulatory taking. Id.,

473 U.S.at 196, 105 S. Ct. at 3121-22. The Court held that because the plaintiff had not shown that

the inverse condemnation procedure was unavailable or inadequate, its taking claim was premature

until it had used those procedures to attempt to obtain just compensation. Id., 473 U.S. at 197, 105

S. Ct. at 3122. 

The Tennessee Supreme Court has interpreted the takings provision of the Tennessee

Constitution and the law of inverse condemnation consistently with the Williamson County holding. 8

Article I, Section 21 of the Tennessee Constitution, the Tennessee takings clause, has been

interpreted as recognizing the right of eminent domain, but also as a limitation on that right “by

entirely prohibiting the taking of private property for private purposes, and by requiring just

compensation when private property is taken for a public use.” Jackson v. Metro. Knoxville Airport

9

Auth., 922 S.W.2d 860, 861 (Tenn. 1996). 

The Tennessee legislature has implemented this constitutional provision through adoption

of eminent domain and inverse condemnation statutes. Edwards v. Hallsdale-Powell Util. Dist., 115
In addition to the provision discussed earlier, Tenn. Code Ann. § 29-16-124 also provides exceptions

10

indicating knowledge or at least attributable knowledge is the key: “saving, however, to unknown owners and

nonresidents, twelve (12) months after actual knowledge of such occupation, not exceeding three (3) years, and saving

to persons under the disabilities of infancy and unsoundness of mind, twelve (12) months after such disability is removed,

but not exceeding ten (10) years.”

-10-

S.W.3d 461, 464 (Tenn. 2003); Jackson, 922 S.W.2d at 861. Both statutory procedures are methods

by which a landowner can enforce the right to just compensation. Inverse condemnation “is a

shorthand description of the manner in which a landowner recovers just compensation for a taking

of property when condemnation proceedings have not been instituted.” Jackson, 922 S.W.2d at 861-

62.

Consequently, inverse condemnation is the method to be used to obtain just compensation,

and the statute of limitations applicable to such actions is the appropriate statute to be applied in the

lawsuit before us. That statute, Tennessee Code Annotated Section 29-16-124, requires landowners

to “commence proceedings within twelve (12) months after the land has been actually taken

possession of, and the work of the proposed internal improvement begun.”

The developer argues that the trial court erred by ruling that the one-year statute of limitations

for inverse condemnation was applicable to his complaint, because the wording of the statute

implicates a different scenario than the one presented by this case. It is true that the language of the

statute envisions a physical possession or intrusion upon the land rather than a regulatory action

preventing use of the land. However, it is clear that inverse condemnation is the appropriate cause

of action here and that the one year statute of limitations applicable to such actions is the correct

statute to use. See Pleasant View Util. Dist. v. Vradenburg, 545 S.W.2d 733, 735 (Tenn. 1977)

(holding that where an entity with the power of eminent domain “destroys, interrupts or interferes

with the common and necessary use of real property of another. . . .” such action constitutes a

“taking,” and the inverse condemnation statute and its related limitations statute apply, even in cases

where there is no actual entry upon the land). The question is not whether the one year statute

applies, but, rather, when does the one year start running.

Under the statute, the triggering event for the running of the statute is the landowner’s

knowledge of the entry onto the land or the beginning of the improvement affecting the land and its

use. Similarly, the triggering event in a regulatory takings case is the date the landowner knew that 10

the government was depriving it of the economic use of its property. In the case before us, that event

occurred when the Commission denied the developer’ application for further development and held

that the developer was required to file for approval a new preliminary plat for the subdivision as a

whole as a prerequisite to further development.

A thorough review of the record in the trial courtshows that the developer’s primary dispute

with the Commission was the Commission’s position that the original approval by Wilson County

of the preliminary plat had lapsed and, consequently, the developer was required to submit a new
Although the developer made some assertions below that the Commission sought to require it to comply with 11

new subdivision regulations, no specific examples have been given. We interpret the assertions as referring to the

requirement that the developer submit a new plat for preliminary approval that complied with Mt. Juliet subdivision

regulations. Any difference between Mt Juliet regulations and Wilson County regulations existing at the time of the

original preliminary approval has not been pointed out.

The merits of the parties’ respective interpretations of the regulations and their application to these facts is 12

not before us. 

The developer’s action in July 1998 in appearing before the Commission to reiterate its argument that no new

13

preliminary plat was required did not re-start the running of the statute of limitations. The Commission had previously

made a final ruling on the issue, and the landowner could not extend its time for bringing a takings action by making a

renewed argument against that ruling.

-11-

preliminary plan. The developer took the position that it did not have to submit a new preliminary

plan.11

The developer was aware of the Commission’s interpretation and application of the

ordinances and regulations to Park Glen in at least March of 1995 when the city informed the

developer, affirming discussion at the March meeting of the Commission, of the requirement. In

fact, the developer’s complaint alleges that “from late 1995 or early 1996,” the city denied permits

for further development. In his deposition, Mr. Campbell indicated that he became aware of the

alleged “taking” of his property right in late 1995 or early 1996.

The Commission’s position was later reaffirmed in a meeting on January 15, 1998, where

the developer appeared and stated its position that no new preliminary plan need be submitted for

approval and the Commission adhered to its interpretation of the regulations. Because the developer 12

claims that the Commission’s decision to require the developer to submit a new preliminary plan was

the arbitrary and illegal action that prevented development, the time for the developer to file an

action began to run, at the latest, on January 15, 1998. This lawsuit was filed May 26, 1999, 13

beyond the one year statute of limitations. Consequently, it is time barred and the trial court

correctly granted the city’s and the Commission’s dispositive motions and dismissed the lawsuit.

On appeal, the developer argues that even if the one year inverse condemnation statute of

limitations were applicable, the entire case should not have been dismissed because the denial of

permits was an ongoing deprivation of the developer’s full use of its property. Consequently, it

argues, the city is still liable for a temporary taking from May 26, 1998, one year before the filing

of the complaint, until June of 2001, when development was permitted. We disagree. The action by

the Commission that prevented further development until the developer complied with the

requirement of a new prelimary plat was clear, definitive, and final. This is not a situation, like in

Del Monte Dunes, where the city kept changing the requirements and stalled on a final decision.

Once the Commission decided that approval of a new preliminary plat was required before

any further development could be approved, the developer had a choice of action. It did not decide

to file the required plat. It did not decide to seek judicial review of the merits of the Commission’s
-12-

interpretation. Instead, it waited for more than a year and filed a lawsuit seeking to compel the

Commission to issue permits and asking for damages for delay in the issuance of such permits. It

simply waited too long, and the action is time barred.

IV. CONCLUSION

We affirm the trial court’s dismissal of the action. Costs of this appeal are taxed to the

appellant, STS/BAC Joint Venture.

___________________________________ 

PATRICIA J. COTTRELL, JUDGE