Exhibit
4.25



Private
and Confidential



CONFIRMATION
MEMORANDUM

SHI HN 1946 - [Actual
name to be confirmed by Owners closer to delivery]



SPECIFIC TERMS IN THIS EXHIBIT HAVE BEEN REDACTED BECAUSE
CONFIDENTIAL TREATMENT FOR THOSE TERMS HAS BEEN REQUESTED. THE REDACTED MATERIAL HAS BEEN SEPARATELY FILED WITH THE SECURITIES
AND EXCHANGE COMMISSION, AND THE TERMS HAVE BEEN MARKED AT THE APPROPRIATE PLACE WITH FIVE ASTERISKS (*****).



GAS-three
Ltd(“Owners”) and Methane Services Limited(“Charterers”) agree upon this Charter
on this 9 May 2011.



Owners
and Charterers are parties to that certain Master Time Charter party dated 9 May 2011 (the “Master Time Charter party”).
Owners and Charterers hereby agree that the terms and conditions contained in the Master Time Charter party (i) shall apply
to the Charter of the Vessel identified in this Confirmation Memorandum and (ii) are incorporated herein by reference.



All
capitalized terms used in this Confirmation Memorandum shall have the meaning set forth in the Master Time Charter party
unless specifically defined herein.



| | 1. | OWNERS
| | -- | ------



The
Owners shall be GAS-three Ltd,a corporation existing under the laws of Bermuda and having its registered office at Clarendon
House, 2 Church Street, Hamilton HM11, Bermuda.



| | 2. | VESSEL DETAILS
| | -- | --------------



|Vessel Name                                                | SHI HN 1946                                   
|---------------------------------------------------------- | ----------------------------------------------
|[Actual name to be confirmed by Owners closer to delivery]
|IMO Number                                                 | [To be confirmed by Owners closer to delivery]
|Vessel Size                                                | 154,800 m3 at 100% fill                       
|Ship Management                                            | Ceres LNG Services Ltd.                       
|Flag                                                       | Bermuda                                       
|Classification Society                                     | ABS                                           
|P&I Club                                                   | UK P&I Club                                   



| | 3. | DELIVERY
| | -- | --------



The
Vessel shall be tendered for delivery by Owners to Charterers safely afloat in all respects ready to receive her first cargo,
Dropping-Last-Outward-Pilot (DLOP) from the building yard. The anticipated delivery date of the Vessel as set out in the building
contract dated May 11, 2010 made between Samsung Heavy Industries Co. Ltd. (“Builder”) and Owners (“Building Contract”),
extracts of which are provided in Annex C of this Confirmation Memorandum, is 31 January 2013 and shall in this Charter be referred
to as “the Anticipated Delivery Date” and the date of actual delivery of the Vessel to Charterer being the “Delivery
Date”.






Page 1
                                                                                                                                                                                                                      of 16





Private
and Confidential



The
Delivery Date will occur after acceptance of delivery of the Vessel by Owners under the Building Contract.



The
Vessel shall be delivered to Charterers immediately after delivery to Owners on the Anticipated Delivery Date. Such Anticipated
Delivery Date may be extended in accordance with the Building Contract, by reason of:

| | (i) | any
                                                                                                                                                                        of
                                                                                                                                                                        the
                                                                                                                                                                        events
                                                                                                                                                                        listed
                                                                                                                                                                        in
                                                                                                                                                                        Article
                                                                                                                                                                        V
                                                                                                                                                                        of
                                                                                                                                                                        the
                                                                                                                                                                        Building
                                                                                                                                                                        Contract,
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------

| | (ii) | statutory
                                                                                                                                                                         modifications
                                                                                                                                                                         to
                                                                                                                                                                         the
                                                                                                                                                                         Vessel
                                                                                                                                                                         under
                                                                                                                                                                         Article
                                                                                                                                                                         IV
                                                                                                                                                                         of
                                                                                                                                                                         the
                                                                                                                                                                         Building
                                                                                                                                                                         Contract,
                                                                                                                                                                         and
| | ---- | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------

| | (iii) | any
                                                                                                                                                                          other
                                                                                                                                                                          reason,
                                                                                                                                                                          provided
                                                                                                                                                                          Charterers
                                                                                                                                                                          provide
                                                                                                                                                                          their
                                                                                                                                                                          full
                                                                                                                                                                          consent.
| | ----- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



Owners
shall provide 30, 15, 10, 7, 5, 4, 3, 2, 1 days notice of the Anticipated Delivery Date. Delays on account of such causes as provided
above in this Clause shall be understood to be permissible delays (“Permissible Delay(s)”) for which revisions in
the Anticipated Delivery Date shall be permitted and are to be distinguished from unauthorised delays for which no revisions in
the Anticipated Delivery Date shall be allowed.



In
the event of a delay in delivery of the Vessel to Charterer caused by a Permissible Delay, the Anticipated Delivery Date will
be considered postponed and the Owners will not be liable for any damages neither indirect nor consequential caused by such delay
in delivery.



If
delivery is delayed beyond ***** from the Anticipated Delivery Date then Charterers shall receive
as liquidated damages the amount of United States Dollars ***** for each day (or part thereof)
by which delivery of the Vessel is delayed and if delayed subsequently beyond *****, Charterers
shall have the option of cancelling this Charter by giving notice thereof to the Owners. Owners
will provide to Charterers regular updates as to the expected delivery date from Builder.



Without
prejudice to anything stated herein, particularly the preceding paragraph, in the event that the Building Contract is cancelled
or terminated for any reason whatsoever (other than by reason of default of the Owners) this Charter shall be terminated with
immediate effect releasing either party from their respective obligations and the Charterers shall not be entitled to any liquidated
or other damages from the Owners.



Delivery
of the Vessel by the Owners to Charterers shall be evidenced by the Protocol of Delivery in the form set out in Annex C, acknowledging
delivery by Owners and acceptance thereof by Charterers, signed by authorised representatives of Charterers and Owners.



| | 4. | REDELIVERY
| | -- | ----------



The
Vessel shall be redelivered on ***** 2018 plus or minus up to ***** at Charterers’ option. Charterers shall redeliver
the Vessel to Owners at the pilot boarding station outbound at last discharge port unless otherwise mutually agreed.
Charterers shall provide 30, 15, 10, 7, 3, 2, 1 days notice of redelivery.



| | 5. | EXTENSION OPTIONS
| | -- | -----------------



Charterers
shall have the option to extend the Charter for ***** periods of ***** each (at Charterer’s option) plus or minus up to
***** at Charterers’ option.



Each
charter extension period and the length of each charter extension period to be nominated by Charterers at least ***** before the
end of each current charter period and shall follow in direct continuation of the then preceding period.








Page 2
                                                                                                                                                                                                                      of 16





Private
and Confidential



The
‘plus or minus’ option must be declared no later than ***** before the notional expiration of the term and will only apply to
the last term in question.



| | 6. | RATE OF HIRE
| | -- | ------------



Charter
Period: The ***** of the Vessel shall be fixed as United States Dollars ***** per day.



First
Option Period: The ***** of the Vessel shall be fixed as United States Dollars ***** per day.



Second
Option Period: The ***** of the Vessel shall be fixed as United States Dollars ***** per day.



The
***** for the Vessel shall be United States Dollars ***** per day and shall be *****; each anniversary year shall begin on 31 January
2010.



| | 7. | PAYMENT OF HIRE
| | -- | ---------------



[To
be confirmed by Owners closer to delivery]



| | 8. | SHIP CONTACT DETAILS
| | -- | --------------------



The
Vessel’s contact details are as follows:

|Telephone | : [To be confirmed by Owners closer to delivery]
|--------- | ------------------------------------------------
|Fax       | : [To be confirmed by Owners closer to delivery]
|E-mail    | : [To be confirmed by Owners closer to delivery]



| | 9. | PERFORMANCE GUARANTEES
| | -- | ----------------------



(a)
Laden Leg Fuel Consumption



|Average Speed  (Knots) | Gas (tonnes) | Fuel Oil (tonnes)
|---------------------- | ------------ | -----------------
|19.5                   | *****        | *****            
|19.0                   |              |                  
|18.5                   |              |                  
|18.0                   |              |                  
|17.5                   |              |                  

No
more than two tonnes of MDO as pilot fuel will be consumed per day.



(b)
Ballast Leg Fuel Consumption



|Average Speed  (Knots) | Gas
    (tonnes) | Fuel Oil (tonnes)
|---------------------- | ---------------- | -----------------
|19.5                   | *****            | *****            








Page 3
                                                                                                                                                                                                                      of 16







Private and Confidential



|19.0 |  | 
|---- |  | 
|18.5 |  | 
|18.0 |  | 
|17.5 |  | 
|17.0 |  | 
|16.5 |  | 
|16.0 |  | 
|15.5 |  | 
|15.0 |  | 
|14.5 |  | 
|14.0 |  | 
|13.5 |  | 
|13.0 |  | 

No more
than two tonnes of MDO as pilot fuel will be consumed per day.



Consumption
figures in the above sub-clauses 8(a) and 8(b) shall be *****.



| | 10. | OUTSTANDING ITEMS
| | --- | -----------------



Owners and
Charterers shall meet in good faith to complete any outstanding items annotated as “[To be confirmed by Owners closer to delivery]”
in this Confirmation Memorandum at least one month prior to delivery of the Vessel.



IN WITNESS WHEREOF,
the Parties have executed this Confirmation Memorandum on the date stated above.



|Agreed and signed by Owners |  | Agreed and signed by Charterers | 
|--------------------------- |  | ------------------------------- | 
|                            |  |                                 | 
|/s/ J. Jensen               |  | /s/ Martin Houston              | 
|Name: J. Jensen             |  | Name: Martin Houston            | 
|                            |  |                                 | 
|Title: Chairman & Director  |  | Title: Attorney-in-Fact         | 
|                            |  |                                 | 
|Date: 9 May 2011            |  | Date: 9 May 2011                | 








Page 4 of 16









Private
and Confidential



ANNEX A –  GAS FORM
C



[To be confirmed by
Owners closer to delivery]








Page 5 of 16









Private
and Confidential



ANNEX B  – LETTER
OF QUIET ENJOYMENT



[Letterhead of Mortgagee]



[To Charterers]



[ • ]



Dear Sirs,



Re:[ • ](the
“Vessel”)



We refer to:



| | a. | the time charter dated [ • ]
                                                            (the “Time Charter”)made between [ •
                                                            ] as owner and you (the “Time Charterer”)as
                                                            charterer in respect of the Vessel;
| | -- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | b. | a loan agreement dated [ • ]
                                                            (the “Loan Agreement”)made between [ •
                                                            ] (the “Owner”)as borrower, us as agent
                                                            and as security trustee (the“Security Trustee”),
                                                            and the financial institutions named on the signature pages therein
                                                            as lenders and swap banks (the “Finance Parties”);
                                                            and
| | -- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | c. | [ • ] the first priority mortgage
                                                            executed by the Owner over the Vessel in our favour between the Owner
                                                            and us (the “Mortgage”).
| | -- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | 1. | References in this Letter to the Time
                                                         Charter or to the Loan Agreement and the Mortgage (together the “Finance
                                                         Documents”) shall include such documents as amended, supplemented
                                                         or varied from time to time so long as any such amendment, supplement
                                                         or variation has been notified to, and agreed by, us. References to paragraphs
                                                         are to paragraphs of this Letter.
| | -- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | 2. | The Security Trustee confirms that:
| | -- | -----------------------------------



| | d. | it has received a copy of the Time Charter and is familiar with their terms; and
| | -- | --------------------------------------------------------------------------------



| | e. | it consents to the Owner’s execution of the Time Charter.
| | -- | ---------------------------------------------------------



| | 3. | In consideration of the sum of US$10.00 and for other good and valuable consideration (receipt
and the sufficiency of which the Security Trustee acknowledges), the Security Trustee undertakes for itself and on behalf of the
Finance Parties not without the Time Charterer’s prior written consent, but subject as provided below and subject to this undertaking
expiring on the expiry of the charter period to:
| | -- | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (a) | issue any arrest, detention or similar proceedings against the Vessel in any jurisdiction; or
| | --- | ---------------------------------------------------------------------------------------------



| | (b) | exercise any power of sale or other disposal of the Vessel or of foreclosure to which the Security
Trustee may be entitled or make any application for the sale of the Vessel or any share therein in any part of the world whether
by public auction or private treaty or otherwise (excluding, for the avoidance of doubt, any steps to be taken solely to protect,
but not enforce, the Finance Parties’ rights in any arrest proceedings or
| | --- | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------








Page 6 of 16









Private
and Confidential



applications
for sale made against the Vessel by any third parties, but only insofar as any such proceedings or applications are continuing
and not permanently stayed, and subject to the condition that the Security Trustee shall cease any such action upon the relevant
proceedings or application being permanently stayed (and release any arrest, or caveat against release, upon the relevant third
party arrest being released) and the Security Trustee shall notify the Time Charterer in writing promptly upon taking or ceasing
any such action); or



| | (c) | take possession of the Vessel; or
| | --- | ---------------------------------



| | (d) | appoint a receiver in respect of the Vessel; or
| | --- | -----------------------------------------------



| | (e) | exercise against the Vessel any right or remedy which would diminish, prejudice or interfere with
the Time Charterer’s rights, options, benefits or privileges under the Time Charter or otherwise interfere with the quiet use and
enjoyment of the Vessel by the Time Charterer under the Time Charter; or
| | --- | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (f) | take any step to wind up, liquidate, or place in administration or receivership the Owner nor commence
or continue any analogous proceedings in any jurisdiction (excluding, for the avoidance of doubt, proving in a liquidation commenced
by any third party, but only insofar as any such proceedings are continuing and not permanently stayed, and subject to the condition
that the Security Trustee shall cease any such action upon the relevant proceedings being permanently stayed and the Security Trustee
shall notify the Time Charterer in writing promptly upon taking or ceasing any such action);
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



SUBJECT
ALWAYS:



| | (i) | to there having occurred no event
                                                             under the Time Charter (a “Charterer’s Termination Event”)
                                                             in consequence of which the Owner, is entitled to terminate and has
                                                             lawfully terminated the Time Charter in accordance with their terms
                                                             including, without limitation, withdrawal of the Vessel from the
                                                             Time Charter by the Owner for non-payment of hire;
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (ii) | to the Vessel not having become an actual, agreed, arranged or constructive total loss and being
no longer available to the Owner;
| | ---- | ----------------------------------------------------------------------------------------------------------------------------------



| | 4. | The Security Trustee agrees that unless
                                                         the Time Charterer is no longer entitled to the use and quiet enjoyment
                                                         of the Vessel under paragraph 3 above, if the Security Trustee enforces
                                                         or exercises its rights pursuant to the Finance Documents in accordance
                                                         with the terms thereof, the Security Trustee may only sell or transfer
                                                         the Vessel expressly subject to the terms of the Time Charter (a “Permitted
                                                         Transfer”) and provided that:
| | -- | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



(a)         the
rights of the Time Charterer under the Time Charter shall be fully preserved and protected following the Permitted Transfer; and



(b)         before
the Permitted Transfer, if the Owner’s rights as “Owner” under the Time Charter are to be assigned or transferred to
a third party, such third party (the “Substitute”) has assumed the rights and obligations of the Owner under
the Time Charter, and



(c)         the
Substitute is acceptable to the Time Charterer acting reasonably.








Page 7 of 16









Private
and Confidential



The Time
Charterer shall give its consent to the proposed Substitute if the Time Charterer is satisfied, acting reasonably, that the validity
and enforceability of the Time Charter will not in any way be prejudiced, and if that Substitute (not being a competitor of the
Time Charterer) has such (i) legal capacity (ii) technical competence and (iii) financial capability as are reasonably required
to become a party and to perform the obligations of the Owner under the Time Charter, and, provided that(but without prejudice
to such Substitute’s ability to meet the foregoing criteria in other circumstances):



| | (a) | arrangements concluded with third parties by the proposed Substitute shall be taken into account
in evaluating its technical competence and financial capability; and
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (b) | in the case of any proposed Substitute which is an affiliate of the Security Trustee, evidence
that it is controlled by the Security Trustee shall be sufficient evidence of financial capability for the purposes of this paragraph
3(a);
| | --- | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



The Owner
undertakes not to make any claim against the Vessel and/or Substitute and/or the Time Charterer arising directly from a Permitted
Transfer made under this Letter.



The Time
Charterer shall use all reasonable endeavours to co-operate with the Security Trustee in order to effect a Permitted Transfer at
the expense of the Security Trustee.



| | 5. | By countersigning this Letter, the Time Charterer
  hereby acknowledges and agrees that:
| | -- | ----------------------------------------------------------------------------------------



| | (a) | subject to the provisions of paragraphs 3 and 4, the enforcement, in accordance with the terms
of the Finance Documents, by the Security Trustee of any security interests granted in favour of the Security Trustee pursuant
to the Finance Documents or the sale or transfer of the Vessel pursuant to the Finance Documents to any other person shall not
constitute a disturbance of the Time Charter or the Time Charterer’s use and quiet enjoyment of the Vessel in accordance with the
terms of the Time Charter;
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (b) | the covenant by the Security Trustee in this Letter is the sole covenant by the Security Trustee
in respect of quiet enjoyment and is in substitution for, and to the exclusion of, any other covenant for quiet enjoyment which
may have otherwise been given by any other party or implied at law or otherwise.
| | --- | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | 6. | The Time Charterer agrees that:
| | -- | -------------------------------



| | (a) | without prejudice to any other rights the Time Charterer may have in respect of any default by
the Owner of any of its obligations under the Time Charter, the Time Charterer will not take any enforcement action in respect
of or otherwise terminate the Time Charter without first notifying the Security Trustee in writing and giving the Security Trustee
the opportunity to remedy (or procure the remedy of) any default by the Owner of any of its obligations under or in connection
with the Time Charter within the relevant period referred to below. Unless the Security Trustee notifies the Time Charterer in
writing that it does not wish to exercise any remedy rights, the Time Charterer will not terminate the Time Charter if the Security
Trustee does so remedy (or procure the remedy of) the default within thirty (30) days of the Time Charterer giving notice to the
Owner (copied to the Security Trustee) of the default by the Owner to perform its obligations under the Time Charter (which cure
period shall be extended to sixty (60) days if it is demonstrated to the Time Charterer (acting reasonably) that the Security Trustee
is continuing to diligently remedy (or procure the remedy of) the default;
| | --- | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------








Page 8 of 16









Private
and Confidential



| | (b) | if the Security Trustee, pursuant to a Permitted Transfer, exercises the power of sale under the
Mortgage and/or assigns or transfers the rights of the “Owner” under the Time Charter to the Substitute, the Time Charterer
will not terminate the Time Charter by reason solely of such transfer (without prejudice to any accrued rights). In such circumstances,
the Time Charterer agrees that the Substitute shall, with effect from the date of the Permitted Transfer and notwithstanding any
other provisions thereof, become a party to the Time Charter in place of the Owner and shall be treated for all purposes as if
the Substitute had originally been named a party in place of the Owner (without prejudice to any accrued rights).
| | --- | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | 7. | The Security Trustee acknowledges that the Time Charterer is not a party to and is not bound by
the provisions of any of the Finance Documents.
| | -- | -----------------------------------------------------------------------------------------------------------------------------------------------



| | 8. | The Security Trustee acknowledges that the terms
  of this Letter shall (subject to such beneficiary similarly confirming and
  consenting to the terms of this Letter) enure to the benefit of the successors
  and assigns of the Time Charterer under the Time Charter.
| | -- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | 9. | The Security Trustee confirms that it has been duly authorised to issue this Letter on behalf of
the Finance Parties and that its issuance conforms with the Loan Agreement and, without limitation, the agency provisions described
therein.
| | -- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | 10. | The terms of this Letter shall be governed
                                                          by and construed in accordance with English law and the provisions of
                                                          Clause 46 (Law and litigation)of the Time Charter shall
                                                          apply, mutatis mutandis, to any dispute arising out of this Letter as
                                                          if such provisions were set out in this Letter.
| | --- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



Please acknowledge
your receipt of and your agreement to the terms of this Letter by signing the attached copy where indicated and returning it to
us.



Each of the parties
signing this Letter intends that the agreement constituted by this Letter shall take effect as a deed notwithstanding the fact
that a party may only sign this Letter under hand.



|Yours faithfully,                                                                                         
|----------------------------------------------------------------------------------------------------------
|                                                                                                          
|for and on behalf of 
[ • ]                                                                               
|                                                                                                          
|We, [ • ]  hereby confirm our agreement to the provisions of this Letter.                                 
|                                                                                                          
|Dated:                                                                                                    
|                                                                                                          
|for and on behalf of 
[ • ]                                                                               
|                                                                                                          
|We, [ • ], for the consideration aforesaid, hereby confirm our agreement to the provisions of this Letter.
|                                                                                                          
|Dated:                                                                                                    
|                                                                                                          
|for and on behalf of
[ • ]                                                                                








Page 9 of 16









Private and Confidential



ANNEX
C –  PROTOCOL OF DELIVERY AND SHIP BUILDING CONTRACT EXTRACTS



ARTICLE IV   CLASS AND REGULATIONS



| | (a) | The Vessel, including its machinery,
  equipment, and outfittings, shall be classed with the American Bureau of Shipping
  (hereinafter called the “Classification Society”), and shall
be built to Class XA1, Liquefied
gas carrier, ship type 2G (Membrane tank, Maximum pressure 25 kPaG and minimum
temperature -163°C), SH, SH-DLA, SHCM, RES, XAMS,
XACCU, SFA(40), NIBS, XAPS,
ENVIRO, PORT, POT, CRC, DFD, UWILD. The Vessel shall comply with all applicable
laws, rules, and regulations. The Vessel shall also comply with recommendations
and requirements set forth in the Specification recommendations and requirements
set forth in the Specifications including those amendments which are being officially
declared, published by the concerned authority and to be compulsory applied to
the Vessel and which shall be brought into force within five (5) years after
Contract (as defined in the ABS’s “Summary
of SOLAS, MARPOL, Load Line, AFS and BWM Requirements to be Compiled with in
2007 and Beyond for All Ship Types - Oct 2009”).
| | --- | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (b) | The Builder, at its expense, shall obtain certificates
as provided in the Specifications and deliver such to the Buyer in triplicate (one (1) original and two (2) copies). If formal
certificate(s) cannot be obtained upon the Vessel’s Delivery, the Builder may furnish provisional one(s) in substitution
for the formal certificate(s). The Builder shall pay the charges for official inspection and certifications required by the Government
of Registry specified in Specifications, and the registration of the Vessel shall be the responsibility of the Buyer.
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (c) | Any revisions to the drawings set forth in Article II
which may be required by the Classification Society shall be implemented by the Builder without any cost to the Buyer; provided
that this will only apply to revisions which are based upon standards of the Classification Society in effect on the date of this
Contract. In the event that there should be any amendments or additions not identified in the Specifications, following the date
of this Contract, to the laws, rules, or regulations of any governmental or regulatory body, or the Classification Society, which
require any compulsory revision(s) of or to the Plans and Specifications or to this Contract, the Buyer shall authorize any such
revision(s) to the Vessel that are necessary to comply with such amendments or additions unless the Buyer shall obtain from such
governmental or regulatory body a written waiver of
| | --- | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



14 of 66



---



Page 10
                                                                                                                                                                                                                      of 16









Private and Confidential



| |  | compliance therewith. In the event that Alterations (as
defined in Article XV(a)) are required, they shall be handled in accordance with
  the provisions of Article XV.
| |  | ------------------------------------------------------------------------------------------------------------------------------------------------------------------------



---





Page 11
                                                                                                                                                                                                                      of 16







Private and Confidential



ARTICLE V   DELIVERY



| | (a) | The Vessel shall be delivered to the Buyer (hereinafter
called the “Delivery”) fully complete, supplied (including lubricating
oil and fresh water in the system but excluding ship’s stores such as food,
utensils, miscellaneous consumables, etc.) and ready for immediate operation,
after having passed the tests and met the standards set forth in the Specifications
and Articles III, IV, and XVII hereof on or before March 31, 2013 (hereinafter
called the “Delivery Date”). The Buyer may delay Delivery beyond
the Delivery Date by giving written notice of the revised date (herein after
called “Revised Delivery Date”) for Delivery not later than two (2)
months before keel laying of the vessel. Buyer may give up to only one (1) notice
for a delay of ninety (90) days. Notwithstanding the foregoing, in the event
defects that could affect the Vessel’s seaworthiness or impair the operation
of Vessel are discovered after the Vessel has passed the tests and met standards
set forth in the Specifications and prior to Delivery of the Vessel, Buyer shall
have the right to require the Builder to make the necessary correction(s) at
the Builder’s expense prior to Delivery.
| | --- | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (b) | The Builder shall use its best efforts and all due diligence
and dispatch, including, but not limited to, the ordering, expediting and inspection of all machinery, parts and materials, to
complete and deliver the Vessel on or prior to the Delivery Date.
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (c) | The Builder shall assist the Buyer to bunker and store
the Vessel (beyond the conditions set forth in Article V(a) above) at Buyer’s expense to be ready for departure. Delivery
shall be made at the Shipyard at a wharf side where there shall be sufficient water for the Vessel always to be afloat and from
which it can safely depart, or at such other safe and secure place as may be mutually agreed. Upon Delivery, the Vessel shall
be free and clear of all liens, encumbrances, taxes and claims of any nature.
| | --- | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (d) | If, at any time, either the commencement of construction,
construction or Delivery of the Vessel or any performance required hereunder as a prerequisite to the Delivery thereof is
| | --- | -----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------





l6 of 66



---



Page 12 
                                                                                                                                                                                                                      of 16







Private and Confidential



delayed
by any of the following events: namely war, acts of state or government, blockade,
  revolution, insurrections, riots, strikes, sabotage, lockouts or other labor
  disturbances (excluding disturbances within the control of the Builder), Acts
  of God, plague or other epidemics, quarantines, prolonged failure or restriction
  of electric current, freight embargoes, earthquakes, tidal waves, typhoons,
  hurricanes, unusually prolonged or unusually severe weather conditions, destruction
  of the premises of works of the Builder or its subcontractors, or of the Vessel,
  or any part thereof, by fire, landslides, flood, lightning, explosion, or other
causes beyond the reasonable control of (and not caused by the actions of) the
  Builder or its subcontractors, as the case may be (collectively called “Force
  Majeure”), then, in the event of delays due to the happening of any of
  the aforementioned contingencies, the number of days by which Delivery is late
  under this Contract (i.e., after the scheduled Delivery Date of the Vessel)
  shall be reduced, subject to the provisions of this Article V(d), by a period
  of time which shall not exceed the total number of working days lost due to
  such delays. Notwithstanding the foregoing, acts of commission or omission
  (irrespective as to negligence and whether voluntary or compulsory) of employees,
  independent contractors or subcontractors, representatives, agents, or others
  engaged by the Builder, including their officers, employees, crews, inspectors,
  and pilots (whether voluntary or compulsory) shall not excuse the Builder for
  delay hereunder.



| | (e) | The Builder shall notify the Buyer in writing within ten
(10) days after the beginning of any period of claimed delay as to the facts establishing that the claimed delay is excusable
pursuant to Article V(d) and the estimated period of delay. The Buyer shall have the right to verify the basis of the claimed
delay and, if there is a disagreement, the issue shall be resolved by arbitration in accordance with the provisions of Article
XXV. An extension of the Delivery Date shall only be allowed if the event(s) above designated adversely affects the Delivery Date
of the Vessel, as determined on the date that the Vessel is actually delivered. Should the Builder fail to timely give required
notice under this Article V(e) demonstrating that the claimed event(s) directly affect the Delivery Date, it shall not be excused
for any such delay.
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (f) | If, following any notice (oral or written) by Builder
of a delay, Buyer determines in its reasonable discretion (taking into account the opinion of Builder), other than due to
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



l7 of 66



---





Page 13 
                                                                                                                                                                                                                      of 16







Private and Confidential



delays caused by the Buyer, that Delivery of the Vessel likely
will be delayed for any reason whatsoever (including without limitation Force Majeure) for a period of more than two hundred (200)
days beyond the Delivery Date, the Buyer shall have the following options:



| | i) | to continue this Contract reserving Buyer’s right
to liquidated damages for the time period that late Delivery is not excused by Force Majeure (if properly claimed) as provided
in Article VIII(a); or
| | -- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | ii) | to cancel this Contract, in which event the Buyer shall
be entitled to a refund in accordance with Article VII(g) and no liquidated damages.
| | --- | --------------------------------------------------------------------------------------------------------------------------------------------



If
Builder gives Buyer written notice of a delay under Article XXVI, Buyer shall have thirty (30) days to exercise the rights under
this subarticle (f) with respect to such delay (though further delays still remain subject to Buyer’s rights under this
subarticle (f)).



| | (g) | i) | Should the Vessel be completed for Delivery before
the Delivery Date and the Builder has so informed the Buyer at least four (4) months in advance of the early delivery date suggested
by Builder, the Buyer may take Delivery at Buyer’s option, but not earlier than 90 days prior to the Delivery Date, provided
that all the terms and conditions of this Contract have been fulfilled.
| | --- | -- | --------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | ii) | If Buyer elects
                                                                               to exercise the option described in (g)(i) above,
                                                                               and if Delivery occurs more than 30 days prior
                                                                               to the Delivery Date, then Buyer agrees to pay
                                                                               Builder an early delivery charge of United States
                                                                               Dollars          for each day in excess of 30 days that the
                                                                               Vessel is delivered early, up to a maximum of 60
days (if the Vessel is delivered 90 or more days early). This charge, if applicable, shall be included with other adjustments due
with the Final Installment. In no event shall there be any charge for early delivery if the Vessel is delivered less than 31 days
early.
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (h) | In any case, the Builder shall notify the Buyer the expected
approximate delivery date during construction in the following manner:
| | --- | -----------------------------------------------------------------------------------------------------------------------------------



18 of 66




Page 14 of 16









Private and Confidential



| | i.) | Five (5) months prior to the expected delivery date notifying
the expected delivery date.
| | --- | -----------------------------------------------------------------------------------------



| | ii.) | Three (3) months prior to the expected delivery date notifying
the scheduled delivery date.
| | ---- | -------------------------------------------------------------------------------------------



| | iii.) | One (1) month prior to the expected delivery date notifying
the scheduled delivery date.
| | ----- | ----------------------------------------------------------------------------------------



| | iv.) | Seven (7) days prior to the expected delivery date notifying
the definite delivery date subject to the satisfactory completion of the sea trials, cryogenic trials and gas trials.
| | ---- | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (i) | Upon Delivery, the Builder shall furnish the Buyer with
the following documents in a  form satisfactory to Buyer:
| | --- | -----------------------------------------------------------------------------------------------------------------



| | i.) | PROTOCOL recording all trials and tests of the Vessel
made pursuant to this Contract and the Specifications.
| | --- | ------------------------------------------------------------------------------------------------------------



| | ii.) | PROTOCOL OF INVENTORY of the equipment of the Vessel,
including spare parts and the like, all as specified in the Specifications.
| | ---- | ---------------------------------------------------------------------------------------------------------------------------------



| | iii.) | PROTOCOL OF CONSUMABLES identifying all fuels, lubricants,
consumable stores, fresh water and liquefied gases supplied by Builder and Buyer remaining onboard at Delivery, including the
original purchase price thereof.
| | ----- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | iv.) | PROTOCOL OF LNG supplied by Builder remaining onboard at
Delivery, including the original purchase price thereof
| | ---- | ----------------------------------------------------------------------------------------------------------------



| | v.) | ALL CERTIFICATES and STATEMENTS OF FACT including the
notarized and legalized BUILDER’s CERTIFICATE required to be furnished upon delivery of the Vessel pursuant to this Contract
and the Specifications.
| | --- | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | vi.) | DECLARATION OF WARRANTY OF FREEDOM FROM LIENS AND CLAIMS
of the Builder that the Vessel is delivered to the Buyer free and clear of any liens, charges, claims, mortgages, or other encumbrances
upon the Buyer’s title thereto,
and in particular, that the Vessel is absolutely free of all burdens in the nature of imposts, taxes or charges imposed by any
governmental authorities
| | ---- | ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



19
of 66






Page 15 of 16





Private and Confidential



(local
as well as national) including any claim by the Guarantor by reason of its Letter of Guarantee under Article XI (as such terms
are defined in such Article) as well as of all liabilities of the Builder to its subcontractors, employees and crew, and of all
liabilities arising from the operation of the Vessel in trial runs, or otherwise, prior to delivery.



| | vii.) | DRAWINGS AND PLANS pertaining to the Vessel as stipulated
in the Specifications.
| | ----- | --------------------------------------------------------------------------------



| | viii.) | COMMERCIAL INVOICE
| | ------ | ------------------



| | ix.) | Notarized and legalized BILL OF  SALE
| | ---- | -------------------------------------



| | x.) | And such other certificates and documents as the Buyer
may request evidencing transfer to the Buyer of a free and clear title in and to the Vessel.
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------



| | (j) | The Buyer shall remove the Vessel from the premises of
the Shipyard within five (5) Business Days after Delivery. If the Buyer does not remove the Vessel from the premises of the Shipyard
within the aforesaid five (5) days, the Buyer shall pay to the Builder the direct and documented costs for anchoring the Vessel
in a safe anchorage outside the Shipyard’s breakwater, such costs to include moving the Vessel to the anchorage, maintaining
the Vessel and restoring the Vessel if necessary. However, the Builder shall take all reasonable steps to minimize such expenses.
The maximum period at anchor shall not exceed 3 weeks from Delivery.
| | --- | ---------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



| | (k) | Upon satisfactory completion of the  trials as specified  in Article XVII, and fulfillment
                                                                              of                                                                               the terms and conditions of this Contract,
                                                                              the Buyer and the Builder shall execute a PROTOCOL OF DELIVERY AND ACCEPTANCE
                                                                              (hereinafter referred to as “Acceptance”). Upon execution of the Acceptance, title and risk of loss of the
                                                                              Vessel                                                                               shall pass to the Buyer. As stated
                                                                              above, it being expressly understood that until such Delivery and Acceptance is effected,
                                                                              title to the Vessel and its equipment (except for the Buyer-furnished Equipment subject to the provisions of Article XII),
                                                                              are vested in the Builder and at its risk.
| | --- | -------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------



20 of 66




Page 16 of 16







AMENDMENT to the SHIPBUILDING CONTRACT



This
letter dated May 4, 2011 is the amendment to the Shipbuilding Contract enteredinto on May 11, 2010 by and between Gas-three
Ltd., a corporation organized and existing under the laws of Bermuda and having its registered
office at Clarendon House,2 Church Street, Hamilton HM11, Bermuda (hereinafter called
the “Buyer”), on the onepart; and Samsung Heavy Industries Co., Ltd.,
a corporation duly organized and existingunder the laws of the Republic of Korea and having its registered office at 1321-15
Seocho-dong, Seocho-gu, Seoul, Korea (hereinafter called the “Builder”), on
the otherpart; and taken together referred to as the “PARTIES”.



WTTNESSETH:



WHEREAS,
the Buyer and the Builder entered into the Shipbuilding Contract forBuilder’s Hull No. l946 dated May 11, 2010;
and



WHEREAS,
the Buyer and the Builder hereby agree to amend the Delivery provisionsin the Shipbuilding Contract.



NOW,
THEREFORE, in consideration of the foregoing premises, the mutual covenantsherein
contained, and other good and valuable consideration, the receipt and legalsufficiency
of which are hereby acknowledged, the PARTIES hereto, intending to belegally bound, hereby agree as follows:



The
following terms and conditions in the Shipbuilding Contract dated May 11, 2010shall be amended as follows:



| | 1. | DELIVERY OF THE VESSEL
| | -- | ----------------------

Clause
(a) in the Article V “DELIVERY” of the Shipbuilding Contract shall be replacedin its entirety with the following:



(a)
The Vessel shall be delivered to the Buyer (hereinafter called the “Delivery”) fullycomplete,
supplied (including lubricating oil and fresh water in the system butexcluding ship’s stores such as food, utensils,
miscellaneous consumables, etc.) and ready for immediate operation, after having passed
the tests and met the standards set forth in the Specifications and Articles III, IV, and XVII hereof on or before January31,
2013 (hereinafter called the “Delivery Date”). The Buyer may delay Delivery beyond
the Delivery Date by giving written notice of the revised date (hereinafter called “Revised Delivery Date”) for Delivery
not later than two (2) months beforekeel laying of the vessel. Buyer may give up to only one (1) notice for a delay of
forty-five (45) days. Notwithstanding the foregoing, in the event defects that could affect
the Vessel’s seaworthiness or impair the operation of Vessel are discovered afterthe
Vessel has passed the tests and met standards set forth in the Specifications andprior
to Delivery of the Vessel, Buyer shall have the right to require the Builder tomake
the necessary correction(s) at the Builder’s expense prior to Delivery.



1







| | 2. | MISCELLANEOUS
| | -- | -------------



Except
as expressly provided in this Amendment, all the other terms and conditions inthe Shipbuilding Contract shall remain unchanged.



IN
WITNESS WHEREOF, the PARTIES hereto have caused this Amendment to be dulyexecuted on the date and year first above written.



| | For and on behalf of Gas-three Ltd.: |  | For and on behalf of Samsung Heavy Industries Co., Ltd.:
| | ------------------------------------ |  | --------------------------------------------------------
| |                                      |  |                                                         
| | /s/ Jeppe Jensen                     |  | /s/ Jaytee Jung                                         
| | Name: Jeppe Jensen                   |  | Name: Jaytee Jung                                       
| | Title: CEO                           |  | Title: Vice President                                   
| | Date:                                |  | Date: 4th May 2011                                      



2