Document ID: s3://data.kl3m.ai/documents/govinfo/USCOURTS/USCOURTS-ca5-11-20912/USCOURTS-ca5-11-20912-0/pdf.json

Parties Involved:
GBP Partners, Limited
Appellant
Maryland Casualty Company
Appellee

Document Text:

IN THE UNITED STATES COURT OF APPEALS

FOR THE FIFTH CIRCUIT

No. 11-20912

GBP PARTNERS, LIMITED, 

doing business as 

Gulfbrook Plaza Shopping Center,

Plaintiff-Appellant

v.

MARYLAND CASUALTY COMPANY,

Defendant-Appellee 

Appeal from the United States District Court

for the Southern District of Texas

USDC No. 4:10-CV-4228

Before JONES, GARZA, and PRADO, Circuit Judges.

EDITH H. JONES, Circuit Judge:*

In September 2008, Hurricane Ike made landfall near Galveston, Texas,

devastating most of the Texas coastline and becoming the costliest hurricane in

Texas history. A shopping center owned by Appellant GBP Partners, Limited

(“GBP”) and insured by Appellee Maryland Casualty Company (“Maryland

Casualty”) was severely damaged by the storm. Maryland Casualty paid to

replace the center’s roof but denied other claims for coverage submitted by GBP,

United States Court of Appeals

Fifth Circuit

F I L E D

January 4, 2013

Lyle W. Cayce

Clerk

 Pursuant to 5TH CIR. R. 47.5, the court has determined that this opinion should not *

be published and is not precedent except under the limited circumstances set forth in 5TH CIR.

R. 47.5.4.

 Case: 11-20912 Document: 00512101501 Page: 1 Date Filed: 01/04/2013
No. 11-20912

and GBP sued in Texas state court. The case was removed to the federal court

for the Southern District of Texas, and the district court granted summary

judgment to Maryland Casualty on all of GBP’s claims. GBP appeals the district

court’s decision. We AFFIRM in part and REVERSE and REMAND in part.

BACKGROUND

After removing this case to federal court based on diversity of citizenship,

Maryland Casualty filed a no-evidence motion for summary judgment, and the

district court granted summary judgment in favor of the insurer on all issues.

GBP’s business is to own and rent space in Gulfbrook Plaza. GBP has no

employees. GBP Plaza L.L.C. is GBP’s general partner. HSA Commercial

Realty Services, L.L.C. (and, previously, a predecessor entity) (collectively,

“HSA”), is a commercial property management company that manages

Gulfbrook. Hardam Azad is a 19% limited partner in GBP, the 100% owner of

GBP Plaza L.L.C., and a 90% owner of HSA. 

Hurricane Ike struck Gulfbrook on September 13, 2008. GBP submitted

a claim to Maryland Casualty, and after investigation Maryland Casualty paid

GBP over $2,300,000 on its claim for roof damage. Maryland Casualty rejected

claims for lost rents, management fees, additional roof damage, and window

damage, however.

The roof damage and loss of electricity at Gulfbrook caused some of the

tenants to close their stores for weeks after the hurricane. The shopping center

itself was closed for about two weeks. Azad offered a twenty-five percent

reduction in rent to Gulfbrook tenants for six months in an effort to encourage

them to stay at Gulfbrook. Gulfbrook’s largest tenant, Affordable Furniture, had

not paid rent for sometime before the hurricane and did not pay rent afterward.

The damage to the roof required it to be completely replaced. Disputes

between GBP and the roofing companies, disputes between GBP and Maryland

Casualty, and delays by GBP in sending Maryland Casualty documents resulted

2

 Case: 11-20912 Document: 00512101501 Page: 2 Date Filed: 01/04/2013
No. 11-20912

in walk-offs by two roofing contractors and extended the roof replacement to over

two years. Significantly, a dispute between GBP and its general contractor

MRCO, Inc. (“MRCO”) led MRCO to refuse to endorse a check from Maryland

Casualty issued as jointly payable to both (as well as to GBP’s lender and GBP’s

public adjuster). Azad forged MRCO’s endorsement and deposited the check. 

After MRCO filed an affidavit of forgery with Maryland Casualty on April 5,

2010, Maryland Casualty indicated to GBP a desire to interplead funds in the

future. GBP refused to execute a proof of loss while Maryland Casualty

continued to consider interpleading the funds. Work stopped in early May after

the second roofing company walked off the job. When GBP ultimately executed

a proof of loss for approximately $1 million on June 29, 2010, Maryland Casualty

issued a final check on July 26, 2010.

Well over two years after Hurricane Ike, GBP commissioned a storefront

window damage report, which alleged that the damage was consistent with a

“prolonged wind event” like a hurricane.

STANDARD OF REVIEW

We “review[ ] the district court’s grant of summary judgment de novo,

applying the same standards as the district court.” Depree v. Saunders, 588 F.3d

282, 286 (5th Cir. 2009). Summary judgment is warranted if the pleadings, the

discovery and disclosure materials on file, and any affidavits show that there is

no genuine issue as to any material fact and that the movant is entitled to

judgment as a matter of law. Id. A motion for summary judgment cannot be

defeated “by submitting an affidavit which directly contradicts, without

explanation, [an affiant’s] previous testimony.” Powell v. Dallas Morning News,

L.P., 776 F. Supp. 2d 240, 246–47 (N.D. Tex. 2011).

Under controlling Texas law, GBP has the burden of establishing that each

of its claims was covered under the Policy. Markel Am. Ins. Co. v. Lennar Corp.,

342 S.W.3d 704, 708–09 (Tex. App.—Houston, 2011, pet. filed). “When covered

3

 Case: 11-20912 Document: 00512101501 Page: 3 Date Filed: 01/04/2013
No. 11-20912

and non-covered perils combine to create a loss, the insured is entitled to recover

only that portion of the damage caused solely by the covered peril.” Id. at 709. 

A failure to establish the amount of loss attributable to covered peril—as

opposed to uncovered peril—is fatal to recovery. Id.

As an insurance policy is a contract, the overall agreement must be

evaluated to determine the purposes the parties had in mind at the time they

formed the contract. Kirby Lake Dev., Ltd. v. Clear Lake City Water Auth.,

320 S.W.3d 829, 841 (Tex. 2010). “Terms in insurance contracts that are subject

to more than one reasonable construction are interpreted in favor of coverage.” 

Gilbert Tex. Constr., L.P. v. Underwriters at Lloyd’s London, 327 S.W.3d 118, 133

(Tex. 2010) (citation omitted). “However, courts should not strain to find an

ambiguity, if, in doing so, they defeat the probable intentions of the parties, even

though the insured may suffer an apparent harsh result as a consequence.” 

Quality Oilfield Prods., Inc. v. Mich. Mut. Ins. Co., 971 S.W.2d 635, 637 (Tex.

App.—Houston, 1998).

DISCUSSION

On appeal, GBP challenges the district court’s grant of summary judgment

to Maryland Casualty on the following disputed claims. We reverse and remand

in part the district court’s decision in regard to lost rent. We affirm the denial

of management fees, roof damage, and window damage.

I. Lost Rents

GBP submitted a claim to Maryland Casualty for rents lost when tenants

were offered a six-month rent abatement in an effort to retain them as tenants

and for an anchor tenant that was not offered a rent abatement, but that

nonetheless was unable to pay its rent and eventually closed. The district court

held that GBP could not show a “suspension of operations,” that the rent

reductions would not qualify as “extra expense” because they were not

“necessary costs,” and that losses due to the loss of power were not covered. GBP

4

 Case: 11-20912 Document: 00512101501 Page: 4 Date Filed: 01/04/2013
No. 11-20912

argues on appeal that the closure of the shopping center qualified as a

“suspension of operations,” that no suspension of operations need be shown to

recover “extra expense,” and that the rent abatements were required to mitigate

loss. Maryland Casualty reiterates the arguments accepted by the district court

and argues that GBP failed to establish causation.

A. Suspension of Operations

The Policy states that Maryland Casualty “will pay for the actual loss of

‘business income’ [Gulfbrook] sustain[s] due to the necessary suspension of

‘operations’ during the ‘period of restoration,’ but not to exceed 12 consecutive

months.” (R. at 551.) “Operations” is defined by the Policy as the “business

activities occurring at [Gulfbrook].” (R. at 563.) It is undisputed that GBP is in

the business of owning and renting shopping center space. It is also undisputed

that at least some of the tenants at Gulfbrook continued to pay rent, including

one that continued to pay rent with no abatement. Under Texas law, a

suspension of operations clause requires business to have completely ceased for

some interval. See, e.g., Apartment Movers of Am., Inc. v. One Beacon Lloyds,

No. 05-10354, 2006 WL 678675, at *1 (5th Cir. Mar. 16, 2006) (requiring

complete interruption where the policy required a “necessary suspension of your

operations”); H & H Hospitality LLC v. Discover Specialty Ins. Co., No. H-10-

1886, 2011 WL 6372825, at *3 (S.D. Tex. Dec. 20, 2011) (requiring complete

interruption where the policy required a “necessary suspension of your

‘operations’”); Quality Oilfield Prods., 971 S.W.2d at 638–39 (requiring complete 

interruption where the policy required a “necessary interruption of business”). 

GBP never ceased its operations, nor has it proved or established a material

question of fact as to whether there was a complete suspension of operations at

the center.

5

 Case: 11-20912 Document: 00512101501 Page: 5 Date Filed: 01/04/2013
No. 11-20912

B. Necessary Extra Expense

The Policy also covers any “necessary ‘extra expense’” GBP incurred

“during the ‘period of restoration’ that [GBP] would not have incurred if there

had been no direct physical loss of or damage to such property caused by or

resulting from a Covered Cause of Loss.” (R. at 551.) “Extra expense” is defined

by the Policy as “necessary costs incurred to . . . [a]void . . . the suspension of

business and continue ‘operations.’” (R. at 563.) The “period of restoration”

begins with “the date of the direct physical loss or damage caused by or resulting

from any Covered Cause of Loss” and ends on the “date when the property . . .

should be repaired, rebuilt or replaced.” (R. at 564.) The Policy covers not just

extra expense associated with a suspension of operations but extra expense

necessary to avoid the suspension of operations. GBP argues just such a purpose

behind the rent abatements. The rent abatements were, according to Azad’s 1

evidence, designed to prevent a possible closure of the entire shopping center

caused by an exodus of tenants due to the hurricane damage. This created a

genuine issue concerning the business necessity of the abatements.2

C. Covered Loss

GBP must still establish that the extra expense was due to a covered loss. 

Power loss is not covered “if the failure occurs away” from Gulfbrook, “however

caused.” (R. at 546.) GBP did not submit any evidence of this type of power loss. 

GBP submitted an affidavit from Azad stating that even if the power had not

failed, GBP would have had to close the building due to the roof damage. (R. at

1297.) Maryland Casualty argues that this affidavit conflicts with previous

sworn statements Azad made during his deposition. On the contrary, Azad’s

The Policy only covers extra expense during the period of restoration. The period of 1

restoration, though, is tied not to a suspension of operations but to the date of a covered loss.

Maryland Casualty cites no authority for its apparent proposition that such rent 2

abatements must be contractually obligated.

6

 Case: 11-20912 Document: 00512101501 Page: 6 Date Filed: 01/04/2013
No. 11-20912

later affidavit does not directly contradict his deposition testimony. Azad’s

affidavit is in agreement with his deposition testimony: both the electrical

outage and the roof damage affected operations.3

GBP did not establish how long the shopping center or parts of it were

closed beyond an admittedly unverifiable statement thatindividual tenants may

have been closed between two and four weeks. (R. at 336.) Although GBP did

not submit additional evidence in support, a sworn affidavit, especially given

that it is undisputed that Gulfbrook sustained significant roof damage from

Hurricane Ike, is sufficient to create a genuine dispute of material fact as to

whether the extra expense was due to the roof damage. Similarly, Azad’s

affidavit is sufficient to establish a genuine dispute of material fact as to

whether the roof damage was sufficient by itself to necessitate closing all or part

of the shopping center, regardless of any power loss. Accordingly, we reverse

and remand to the district court on the question whether the rent abatements

were a “necessary extra expense” due to a “covered loss.”

D. Affordable Furniture

GBP did not submit evidence that it incurred an extra expense to avoid a

suspension of operations tied to Affordable Furniture. GBP made no change to

its informal policy regarding Affordable Furniture after Hurricane Ike. Rather,

it continued its existing practice of allowing Affordable Furniture to pay rent

late. Absent a suspension of operations or an expense tied to an attempt to avoid

a suspension of operations, there is no covered loss. Accordingly, the district

Azad replied “Yes” when asked if Gulfbrook “suspended operations for two weeks due 3

to the loss of electricity[.]” (R. at 335.) But in answering the very next question (regarding the

exact period operations were suspended), Azad referenced a roof that was “totally

compromised.” Id. Shortly thereafter, Azad states that “even when [Gulfbrook’s tenants] are

open, they are continue [sic] to sustain damages because the roof is constantly leaking.” Id.

In his affidavit, Azad states that “[e]ven if portable electrical generators had been brought into

the property, the roof damage itself caused a total suspension of operations.” (R. at 1297.)

7

 Case: 11-20912 Document: 00512101501 Page: 7 Date Filed: 01/04/2013
No. 11-20912

court correctly granted summary judgment to Maryland Casualty for lost rents

from Affordable Furniture.

II. Management Fees

As GBP had no employees, it paid HSA (and an HSA-predecessor

company) to manage its properties. A new management agreement was signed

on January 1, 2009, shortly after Hurricane Ike struck. The new management 4

agreement raised HSA’s compensation for work on insurance claims from $75 to

$100 an hour. (R. at 2012.) Maryland Casualty refused to pay GBP’s claim for

these fees, and the district court granted Maryland summary judgment on the

basis that the Policy did not cover that type of work and the fees were not an

extra expense because there was no suspension of operations. GBP argues that

some of the fees fall within the component of business income coverage for

“[c]ontinuing normal operating expenses” and some of the fees were a covered

“extra expense.” Maryland Casualty responds that the new agreement was not

necessary to obtain the repairs or negotiate insurance matters, and the

management fees are not a proper business income claim. We agree with

Maryland Casualty.

First, the Policy only covers “[c]ontinuing normal operating expenses

incurred,” (R. at 562), if there is a suspension of operations. Because no

suspension of operations occurred, the recurring management fees cannot be

fully recoverable. 

Second, GBP offered no evidence explaining what portion of the fees

directly related to making emergency repairs and securing recovery from

insurance claims or legal proceedings. As explained above, GBP can recover as

extra expense only costs necessary to avoid a suspension of operations. Although

its brief mentions “emergency repairs (necessary to protect the property or safety

As owner of GBP’s general partner and majority owner of HSA, Azad signed for both 4

parties.

8

 Case: 11-20912 Document: 00512101501 Page: 8 Date Filed: 01/04/2013
No. 11-20912

of tenants)” and that “management fees necessary to initiate and manage the

repair process were incurred by GBP during the period of restoration and would

not have been incurred had there been no property damage from a covered

cause,” (Appellant’s Br. 17–18), GBP did not submit evidence tying fees directly

to its efforts to prevent a suspension of operations due to an exodus of tenants,

as opposed to non-covered costs. On the contrary, GBP references those

management fees in conjunction with fees directly related to non-covered costs.5

III. Roof Damage

Gulfbrook’s roof sustained additional damage due to delays in its

replacement. GBP was also unable to obtain a warranty on the new roof and

sought recovery of the loss in warranty value. Maryland Casualty refused to pay

for either. The district court agreed with Maryland Casualty that GBP caused

the delay that led to the damage. The relevant facts are undisputed.

MRCO served as GBP’s initial roof contractor. GBP fired MRCO on

October 9, 2009 after a dispute. Maryland Casualty’s third check to GBP for the

roof claims was issued on October 6, 2009, and GBP apparently did not receive

it until after firing MRCO. Like the first two checks, this check was jointly

payable to GBP, MRCO, GBP’s lender, and GBP’s public adjuster. When MRCO

refused to endorse the check, Azad forged MRCO’s endorsement and deposited

“[C]onsiderable time has been (and remains to be) expended on GBP’s behalf to find,

5

evaluate, hire, and oversee the public adjusters, contractors, attorneys, and others needed to

work through the process of identifying and estimating the costs to repair the damage,

compiling the information necessary to pursue the insurance claims, and conducting the repair

work.” (Appellant’s Br. 17.)

GBP also fails to cite any authority in support of the proposition that the management

fees are not an excluded “other consequential loss.” Contra Southeast Real Estate Invest. Corp.

v. Nationwide Mut. Ins. Co., No. 1:07cv1197, 2008 WL 4939748, at *5 (S.D. Miss. Nov. 17,

2008) (holding that percentage management fees were “‘unquestionably’ any other

consequential loss”). The discussion in GBP’s reply brief about consequential damages is

inapposite because it deals entirely with damages from a breach, and GBP does not allege that

the management fees were incurred because of a breach of contract by Maryland Casualty.

(Appellant’s Reply Br. 6–7.)

9

 Case: 11-20912 Document: 00512101501 Page: 9 Date Filed: 01/04/2013
No. 11-20912

the check. MRCO provided an affidavit of forgery to Maryland Casualty on April

5, 2010, and Maryland Casualty informed GBP it would need to file an

interpleader. Maryland Casualty ultimately never did so. GBP, GBP’s public

adjuster, and Maryland Casualty continued to work together, and Maryland

Casualty sent GBP a proposed proof of loss on May 5, 2010. GBP’s second

roofing contractor walked off the job in early May of 2010. GBP did not execute

a proof of loss until June 29, 2010. Maryland Casualty issued a check based on

the proof of loss within the thirty-day time frame required under the Policy.

GBP argues that the additional damages to the roof resulted from those

delays. Many of the delays were caused by GBP. GBP argues, however, that

Maryland Casualty is nonetheless responsible for GBP’s own dilatory actions

because Maryland Casualty considered interpleading further payments after

GBP’s principal forged an endorsement on a check issued by Maryland Casualty,

and GBP was thus justified in not executing a proof of loss to avoid an

interpleader. Even interpreting the facts in the light most favorable to GBP as

the non-movant, the district court correctly granted Maryland Casualty

summary judgment on this issue. Also, because, by GBP's own admission, the

loss of warranty value was caused by the delays to the roof replacement, the

question of whether the loss warranty value would have otherwise been covered

need not be reached. Maryland Casualty did not breach its payment obligation.

IV. Window Damage

GBP’s consultant did not inspect the windows at Gulfbrook until early

2011, and GBP did not file a proof of loss for the alleged window damage until

June of 2011. Maryland Casualty then performed its own inspection and denied

GBP’s claim. The district court granted summary judgment for Maryland

Casualty because GBP did not provide timely notice of loss or create a genuine

10

 Case: 11-20912 Document: 00512101501 Page: 10 Date Filed: 01/04/2013
No. 11-20912

issue that the damage to the windows was caused by Hurricane Ike rather than

a non-covered peril.6

Regardless of the timeliness of its notice, GBP’s claim for window damage

must fail because GBP did not offer evidence to establish what part of the

damage to the windows was caused by Hurricane Ike as opposed to some other

non-covered event. Markel, 342 S.W.3d at 709. Moreover, GBP has waived the

argument by inadequately briefing the issue on appeal. See FED. R. APP.

P. 28(a)(9)(A); Beaumont, 972 F.2d at 563. An allegation of allocation without

further explanation than this: “the wear and tear, etc., are the part that did not

require replacement; the hurricane damage is the part that did”–is insufficient

as a matter of law. (Appellant’s Reply Br. 9–10.)7

CONCLUSION

The district court did not err in granting summary judgment in favor of

Maryland Casualty on any issue other than the rent abatements. Accordingly,

we AFFIRM the judgment on all other issues and REVERSE and REMAND to

the district court for further proceedings in connection with the rent abatement.

The Policy excludes damage resulting from wear and tear, deterioration, hidden or 6

latent defect, settling, cracking, shrinking expansion, continuous or repeated seepage or

leakage of water that occurs over a period of 14 days or more. (R. at 546-48.)

GBP raised a number of non-contractual issues to the district court and sought 7

extra-contractual damages. The district court granted GBP summary judgment on all of these

issues, and GBP chose not to argue them on appeal. Failure to raise an issue on appeal

constitutes waiver of that argument. United States v. Thibodeaux, 211 F.3d 910, 912 (5th Cir.

2000); Yohey v. Collins, 985 F.2d 222, 224–25 (5th Cir. 1993).

11

 Case: 11-20912 Document: 00512101501 Page: 11 Date Filed: 01/04/2013