Source: s3://data.kl3m.ai/documents/govinfo/USCOURTS/USCOURTS-ca8-04-03546/USCOURTS-ca8-04-03546-0/pdf.json

Nature of Suit Code: 893
Nature of Suit: Environmental Matters
Cause of Action: 

---

United States Court of Appeals

FOR THE EIGHTH CIRCUIT

___________

No. 04-3546

___________

Arkansas Wildlife Federation, an *

Arkansas Not-For-Profit Corporation; *

The National Wildlife Federation, a *

District of Columbia Not-For-Profit *

Corporation; Arkansas Nature Alliance, *

an Arkansas Not-For-Profit Corporation;*

The Hampton Landing Property Owners'*

Association, an Arkansas Not-For- *

Profit Corporation; The White River * 

Conservancy, an Unincorporated *

Association; The Augusta Improvement *

Club, an Arkansas Not-For-Profit *

Corporation; Kenneth L. Rose; E. W. *

Ray; Charles Bowerman; Tommy M. *

Castleberry, Sr.; Greg Rawn; Oliver M. *

Eichelmann; Everett G. Oates; David *

Carruth, *

*

Plaintiffs-Appellants, *

* Appeal from the United States

v. * District Court for the

* Western District of Arkansas.

United States Army Corps of *

Engineers; Jack Scherer, Colonel, *

District Engineer, Memphis District, *

U.S. Army Corps of Engineers; Don T. *

Riley, Brig. General, President, *

Mississippi River Commission, *

*

Defendants-Appellees. *

Appellate Case: 04-3546 Page: 1 Date Filed: 12/20/2005 Entry ID: 1987757
1

The Honorable G. Thomas Eisele, United States District Court for the Western

District of Arkansas.

-2-

___________

Submitted: October 10, 2005

Filed: December 20, 2005

___________

Before ARNOLD, BOWMAN, and MURPHY, Circuit Judges.

___________

MURPHY, Circuit Judge.

Appellants brought this case against the United States Army Corps of

Engineers alleging that the Corps had violated the National Environmental Policy Act

(the Act) in connection with its Grand Prairie Area Demonstration Project (the

Project) in East Central Arkansas and seeking declaratory and injunctive relief. Both

sides moved for summary judgment, and the district court1

 granted judgment to the

Corps. Appellants argue on their appeal that the cumulative impact analysis in the

Final Environmental Assessment (FEA) was inadequate and that a Supplemental

Environmental Impact Statement (SEIS) should have been prepared. We affirm.

The Grand Prairie Region consists of over 500,000 acres located between

Mississippi and Arkansas, and it is a major rice producing area. This region relies on

groundwater primarily from the Alluvial Aquifer and the Sparta Aquifer. The

Alluvial Aquifer provides ninety percent of the agricultural water used in the region,

and it will be depleted by 2015 unless protective action is taken. Depletion of the

Alluvial Aquifer would cause severe economic hardship to the region; seventy seven

percent of the irrigated crop would be lost, and rice production would decline by

twenty three percent. The Sparta Aquifer provides drinking water to local residences

and supplies the water needs of local industry, but the suitability of its drinking water

Appellate Case: 04-3546 Page: 2 Date Filed: 12/20/2005 Entry ID: 1987757
2

 In addition to AWF, plaintiffs included the National Wildlife Federation,

Arkansas Nature Alliance, the Hampton Landing Property Owners' Association, the

White River Conservancy, the Augusta Improvement Club, Kenneth L. Rose, E. W.

Ray, Charles Bowerman, Tommy M. Castleberry, Sr., Greg Rawn, Oliver M.

Eichelmann, Everett G. Oates, and David Carruth. For ease of reference we adopt the

usage of the parties in their briefs by referring to appellants collectively as AWF.

-3-

will eventually be destroyed if it continues to be diverted for other uses as the

Alluvial Aquifer is depleted.

The Grand Prairie Project was designed by the Corps to allow continued

irrigation of the agricultural region while preserving the Alluvial Aquifer. The Corps

issued a draft Environmental Impact Assessment (EIS) for public comment in early

1998. In July 1998 in response to the public comments, the Corps issued a draft

General Reevaluation Report (GRR). The Final Environmental Impact Assessment

(FEIS) was issued in 1999, and a Record of Decision (ROD) was signed in 2000. The

FEIS and ROD selected "Alternative 7B" as the plan to be implemented. The Project

has five components: (1) conservation of water by increasing agricultural efficiency

of water usage, (2) reduction of water withdrawals from the Alluvial Aquifer so that

there is no net loss of water and an end to drawing on the Sparta Aquifer for

irrigation, (3) additional on farm reservoirs, (4) construction of a system that would

pump excess water from the White River into the Grand Prairie region, and (5)

various environmental improvement features. Since the signing of the ROD in 2000,

twenty four percent ($71,000,000) of the total estimated cost of the Project

($319,000,000) has already been invested.

Arkansas Wildlife Federation (AWF)2

 filed suit in February, 2004, alleging that

the Corps had failed to comply with the Act and seeking a preliminary and permanent

injunction against the construction of the water import feature of the Project. AWF

alleged that the Corps had not considered all reasonably feasible alternatives before

adopting Alternative 7B, that the FEIS and ROD had not adequately considered the

Appellate Case: 04-3546 Page: 3 Date Filed: 12/20/2005 Entry ID: 1987757
3

 The regulatory definition of tiering is as follows: "'Tiering' refers to the

coverage of general matters in broader environmental impact statements with

subsequent narrower statements or environmental analyses incorporating by reference

the general discussions and concentrating solely on the issues specific to the

statement subsequently prepared." 40 C.F.R. § 1508.28.

-4-

cumulative impacts of the proposed project, that the Corps had not adequately

considered the direct and indirect impacts of the Project on the White River basin,

and that the Corps improperly tiered3

 the minimum flow requirements of the Arkansas

State Water Plan to the FEIS.

In March, 2004 the Corps issued for public comment a Draft Environmental

Assessment (DEA) and a Finding of No Significant Impact (FONSI). The DEA

included a list of proposed changes to the original plan, including (1) converting 29

miles of canals into pipelines, (2) providing water delivery by pipeline instead of

existing streams, (3) use of 113 acres of borrow pits to store materials for

constructing levees instead of hauling material from a farther distance, (4)

construction of a separate building to house the control system, (5) widening of a

canal, (6) alignment changes to canals and pipelines, (7) replacement of canal 3200

with multiple small pipelines, and (8) rehabilitation of existing reservoirs. 

The Corps issued a Final Environmental Assessment (FEA) and a FONSI in

July 2004 which approved the changes proposed in the DEA. The Corps determined

that the changes adopted by the FEA were minor and would cause no significant

unmitigated environmental impacts not already considered and that preparation of a

SEIS was therefore not required. AWF amended its pleadings to challenge this

finding and argued that a SEIS was required.

Both sides moved for summary judgment. The district court found that AWF's

four year delay in challenging the FEIS, GRR, and ROD was unreasonable and that

those claims were barred by laches. Alternatively, the district court held that the

Appellate Case: 04-3546 Page: 4 Date Filed: 12/20/2005 Entry ID: 1987757
-5-

Corps had complied with the Act in connection with the FEIS, GRR, and ROD. The

court additionally held that the Corps had adequately considered the cumulative

impacts and the direct and indirect effects of the Project and that a SEIS had not been

required following the changes adopted by the FEA. AWF appeals, arguing that the

district court erred in finding no SEIS was required because the cumulative impact

analysis by the Corps had been inadequate, substantial changes in the Project had

been made, and significant new information had been discovered. 

We review the district court's grant of summary judgment de novo. Nunley v.

Department of Justice, 425 F.3d 1132, 1135 (8th Cir. 2005), but challenges to agency

action are reviewed for whether it was arbitrary and capricious. 5 U.S.C. § 706(2)(A);

Marsh v. Oregon Natural Resources Council, 490 U.S. 360, 374 (1989). We are not

free to substitute our own judgment for that of the agency, but rather our role is to

"ensure that the agency has adequately considered and disclosed the environmental

impact of its actions." Mid-States Coalition for Progress v. Surface Trans. Bd., 345

F.3f 520, 534 (8th Cir. 2004)(quoting Baltimore Gas & Elec. Co. v. Natural

Resources Defense Council, Inc., 462 U.S. 87, 98 (1983)).

I.

AWF contends that neither the FEIS nor the FEA adequately considered the

cumulative impacts of past, present, and future action on the Project. In order to

evaluate the FEA properly AWF argues we must first review the adequacy of the

FEIS. The Corps responds that AWF's failure to appeal the district court's ruling on

laches prevents it from now challenging the adequacy of the cumulative impact

analysis in the FEIS. AWF contends that it is not challenging the FEIS directly, but

rather arguing that the FEIS was not sufficiently comprehensive to permit its

cumulative impact analysis to serve as the basis for that in the FEA. It asserts that it

was therefore improper for the FEA to incorporate or be "tiered" upon the FEIS's

cumulative impact analysis. 

Appellate Case: 04-3546 Page: 5 Date Filed: 12/20/2005 Entry ID: 1987757
-6-

Although we have implied that any prior environmental impact statement (EIS)

should be reviewed in determining whether an FEA is adequate, Newton County

Wildlife Ass'n v. Rogers, 141 F.3d 803, 809 (8th Cir. 1998); Sierra Club v. U.S.

Forest Service, 46 F.3d 835, 840 (8th Cir. 1995), there appears to be no case

indicating that such a rule should apply to an FEIS when review of it is barred by

laches. We need not address the question of whether laches bars consideration of this

FEIS as it relates to the FEA, however, because we conclude that the cumulative

impact analysis in both the FEIS and the FEA was adequate. 

The Act requires that the agency proposing any action which may significantly

affect the environment study and consider the environmental impacts of the proposed

action, any unavoidable adverse environmental impacts, and the relationship between

local short term uses of the environment and long-term productivity. 42 U.S.C. §

4332(C). This requires study of the direct, indirect, and cumulative impacts of the

proposed action. 40 C.F.R. § 1508.25. Cumulative impacts, a focus of this appeal,

are "the impact[s] on the environment which result[] from the incremental impact of

the action when added to other past, present, and reasonably foreseeable future

actions regardless of what agency (federal or non-federal) or person undertakes such

action." 40 C.F.R. § 1508.7. 

In complaining that the FEIS only lists additional projects, but does not analyze

the cumulative environmental impacts, AWF relies on statements of the

Environmental Protection Agency, the Fish and Wildlife Service, and other state and

private organizations critical of the cumulative impact analysis by the Corps.

Although other government agencies urged the Corps to wait for the completion of

comprehensive studies of the White River basin by other entities, the Act only

requires that the Corps consider and respond to the comments of other agencies. The

Act does not require the Corps to wait for other agencies to complete their studies,

Environmental Defense Fund, Inc. v. Hoffman, 566 F.2d 1060, 1068 (8th Cir. 1977),

or to accept the input or suggestions of other agencies. Custer County Action

Appellate Case: 04-3546 Page: 6 Date Filed: 12/20/2005 Entry ID: 1987757
-7-

Association v. Garvey, 256 F.3d 1024, 1038 (10th Cir. 2001). It is up to the Corps

to decide which comments of other agencies are of value to its projects, see Citizens

Against Burlington, Inc. v. Busey, 938 F.2d 190, 201 (D.C. Cir. 1991), and we are

hesitant to second guess its judgment.

A FEIS complies with the Act so long as the agency takes a "hard look" at the

environmental impacts of the proposed action. City of Richfield, Minn. v. F.A.A., 152

F.3d 905, 906 (8th Cir. 1998). Here, the FEIS addressed the cumulative impact of the

Project in connection with numerous other projects, including four existing projects,

two pending projects, three unauthorized and unfunded projects, and five other

actions affecting the White River. The FEIS also addressed the cumulative impact

of potential irrigation projects which are not reasonably foreseeable under 40 C.F.R.

§ 1508.7. After our review of the record, we conclude that the Corps did not abuse

its discretion in considering the cumulative impact in the FEIS.

AWF complains that the cumulative impact analysis in the FEA is inadequate,

that it lacks the detailed information required by the Act, and that its findings are

conclusory. AWF argues that the neither the "past actions" nor "present actions"

section of the FEA adequately addresses the cumulative impact of the Project on the

White River. Appellants' argument is premised on the incorrect assumption that the

FEIS was inadequate. The Act encourages agencies to tier a subsequent

Environmental Assessment (EA) to an EIS to save money and time by avoiding

repetitive inquiries, 40 C.F.R. § 1502.20, and to help the agency "focus on issues

which are ripe for decision and exclude from consideration issues already decided or

not yet ripe." 40 C.F.R. § 1508.28. 

An FEA will be ruled deficient only if it does not include a cumulative impact

analysis or is not tiered to an EIS that contains such an analysis. See Native

Ecosystems Council v. Dombeck, 304 F.3d 886, 895-96 (9th Cir. 2000). Although

tiering an EA on an EIS will not always cure deficiencies in the cumulative impact

Appellate Case: 04-3546 Page: 7 Date Filed: 12/20/2005 Entry ID: 1987757
-8-

analysis in the EA, see Klamath-Siskiyou Wildlands Center v. Bureau of Land, 387

F.3d 989, 997-98 (9th Cir. 2004), an FEA cannot "be both concise and brief and

provide detailed answers for every question." Sierra Club, 46 F.3d at 840. Because

the FEA was properly tiered upon the FEIS and because the FEA provided an updated

and adequate analysis of any new environmental impacts, we conclude that the

cumulative impacts of the Project were properly considered in compliance with the

Act.

Finally, AWF complains that both the FEIS and the FEA improperly deferred

the study of the cumulative impacts of reasonably foreseeable action. An impact is

reasonably foreseeable if it "is sufficiently likely to occur that a person of ordinary

prudence would take it into account." United States v. Dubois, 102 F.3d 1273, 1287

(1st Cir. 1996). This determination is left to the Corps in the first instance. See Kern

v. United States Bureau of Land Management, 284 F.3d 1064, 1069 (9th Cir. 2002).

Both the FEIS and the FEA considered the "probable environmental consequences"

of the proposed action, see Friends of the Boundary Waters Wilderness v. Dombeck,

164 F.3d 115, 1130 (8th Cir. 1999), and we see no reason to second guess their

judgment. AWF's reliance upon our decision in Mid-States Coalition for Progress is

misplaced since the agency in Mid-States stated that a particular outcome was

reasonably foreseeable and that it would consider its impact, but then failed to do so.

Mid-States, 345 F.3d at 550. Here, the Corps has not "completely ignored" the

cumulative impact of future projects, but has considered the cumulative impact of

projects in the region, some of which are not reasonably foreseeable. We conclude

that the cumulative impact analysis in the FEIS and FEA complied with the Act. 

II.

AWF complains that the Corps was required to prepare a SEIS, which is

required if the agency "makes substantial changes in the proposed action that are

relevant to environmental concerns" or "there are significant new circumstances or

Appellate Case: 04-3546 Page: 8 Date Filed: 12/20/2005 Entry ID: 1987757
-9-

information relevant to environmental concerns." 40 CFR § 1502.9(c). This section

is interpreted to require a SEIS "if the changed plans or circumstances will affect the

quality of the human environment in a significant manner...not already considered by

the federal agency." Airport Impact Relief, Inc. v. Wykle, 192 F.3d 197, 204 (1st Cir.

1999); Marsh, 490 U.S. at 374. 

AWF argues that the FEA contains at least six substantial changes not

previously considered: an eighty two mile decrease in the miles of canals used, the

one hundred thirteen mile increase in the miles of pipeline used, the reduction in the

use of natural streams in favor of pipelines, doubling the acres of permanent upland

hardwood impacts, the construction of borrow pits to store machinery, and widening

Canal 1000 to create a one hundred acre reservoir. The Corps responds that the

changes are not substantial because they will not have a significant impact on the

environment which has not already been considered. In addition, it asserts that the

changes will not significantly alter the areas served, the costs, the project purposes,

or the White River basin. 

A change is substantial if it presents a "seriously different picture of the

environmental impact." South Trenton Residents Against 29 v. Fed. Highway

Admin., 176 F.3d 658, 663 (3d Cir. 1999); see also Hickory Neighborhood Defense

League v. Skinner, 893 F.2d 58, 63 (4th Cir. 1990); Sierra Club v. Froehlke, 816 F.2d

205, 210 (5th Cir. 1987). To determine whether a change is substantial we look at the

possible environmental consequences not previously considered. Marsh, 490 U.S. at

374. 

The record demonstrates that AWF has overstated the overall impact of the

changes on the environment. The concern over replacing canals with pipelines is

misplaced because most of the canals in the original plan were not functional and

would require substantial excavation work. The draft EA also explained that

pipelines were less damaging to existing habitats than canals and would have fewer

Appellate Case: 04-3546 Page: 9 Date Filed: 12/20/2005 Entry ID: 1987757
-10-

impacts associated with construction. While the reduction of natural stream use will

reduce some of the fisheries benefits initially heralded by the Corps, it will be very

minor (only 99 of 8,560 fish habitats will be lost) and will be balanced by the

reduction of potential adverse impacts to riparian vegetation and zebra mussel

introductions. Moreover, the reduction of the use of natural streams for water

delivery resulted from public comments that criticized the use of natural streams in

the initial proposal. The proposed changes also reduce the acres of upland hardwood

that are temporarily and permanently affected by the Project, instead of increasing the

impact on them. The excavation for the borrow pits does not change the volume of

soil required for the project, but only where that soil comes from. Use of the pits

substantially reduces hauling costs and will not result in the loss of wildlife habitat.

Finally, nothing in the record indicates that the creation of Canal 1000 would

adversely impact the region. 

The Corps adequately considered the environmental impact of the proposed

changes and reasonably concluded that they were not significant and that any

environmental impact appears to be positive rather than negative. Although we do

not hold that a reduction in the environmental impact can never trigger the

requirement to prepare a SEIS, "a reduction in the environmental impact is less likely

to be considered a substantial change relevant to environmental concerns than would

be an increase in the environmental impact." Friends of the Bow v. Thompson, 124

F.3d 1210, 1218-19 (10th Cir. 1997). 

AWF's reliance on DuBois v. United States Dep't of Agriculture, 102 F.3d

1273 (1st Cir. 1996) is unpersuasive. In DuBois an agency adopted an alternative

that had never before been considered nor disseminated for public comment, but

appeared for the first time in the FEIS. DuBois, 102 F.3d at 1292. The First Circuit

held that under these circumstances the agency was required to submit a SEIS. In

contrast, the proposed changes in the Project were presented for public comment and

the FEA considered the potential environmental implications of these changes.

Appellate Case: 04-3546 Page: 10 Date Filed: 12/20/2005 Entry ID: 1987757
-11-

Furthermore, unlike DuBois, the change in the Project is one of design, not the

selection of a completely new and unconsidered alternative. Because determining

whether an impact is substantial is "a classic example of a factual dispute the

resolution of which implicates substantial agency expertise," we defer to the Corps'

informed discretion. Marsh, 490 U.S. at 376.

AWF also argues that new information indicates that water removal from the

White River will be greater than initially planned and that this requires preparation

of a SEIS. Appellants complain that the FEA contains references to a number of

projects that were either not mentioned in the FEIS or whose cumulative impacts

were not adequately considered in the FEIS. The Corps responds that whether the

new information is significant enough to require a SEIS is a decision that should be

left to the informed discretion of the agency. The Corps states that while there is new

information in the FEA, it merely updates material already contained in the FEIS and

does not alter the overall picture of the environment. Although the FEA mentions a

number of new irrigation projects not considered in the FEIS, those projects are so

new as to be speculative and are thus not significant.

When new information is presented, the agency is obligated to consider and

evaluate it and to make a reasoned decision as to whether it shows that any proposed

action will affect the environment in a significant manner not already considered.

Marsh, 490 U.S. at 374. Our role is limited to verifying that the agency considered

the relevant factors and did not make a clear error in judgment. Id. at 378. An agency

does not have to provide a SEIS every time new information comes to light; "to

require otherwise would render agency decisionmaking intractable, always awaiting

updated information only to find the new information outdated by the time a decision

is made." Marsh, 490 U.S. at 374. Here, many of the projects briefly discussed in the

FEA were discussed in more detail in the earlier FEIS upon which the FEA was

properly tiered. Those projects mentioned which were new were very early in their

Appellate Case: 04-3546 Page: 11 Date Filed: 12/20/2005 Entry ID: 1987757
-12-

planning. We conclude that the Corps did not act arbitrarily or capriciously in

refusing to prepare a SEIS based on new information. 

III.

This Project has proceeded through various stages over a period of years with

much involvement of interested parties. As has been pointed out, "the NEPA process

involves an almost endless series of judgment calls[,] .... [t]he line-drawing decisions

necessitated by this fact of life are vested in the agencies, not the courts," Coalition

on Sensible Transportation, Inc. v. Dole, 826 F.2d 60, 66 (D.C. Cir. 1987). After

studying the record, we conclude that AWF has not shown that the Corps acted in an

arbitrary or capricious manner. The judgment of the district court is therefore

affirmed.

______________________________

Appellate Case: 04-3546 Page: 12 Date Filed: 12/20/2005 Entry ID: 1987757