Urwashanza/europrocure-10-public-procurement huggingface dataset:
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: Empa Immobilienmanagement
Country: CH
Contract type: Works
Procedure: Open procedure
CPV classification: 45210000: Building construction work
Submission deadline: 2021-03-01
Award criteria: The most economic tender

Technical requirements: Am WSL–Instituts für Schnee- und Lawinenforschung in Davos Dorf wird der Ersatzneubau Haus D ausgeschrieben.
Die Konstruktion erfolgt in präfabriziertem Holzskelletbau mit Holzbetonverbunddecken und mit aussteifender Bodenplatte und Kern in Ortbeton.
Die bestehende Montagehalle muss während der Bauzeit in Betrieb bleiben und kann erst nach Inbetriebnahme der neuen Montagehalle im Neubau abgebrochen werden.
Eine provisorische Werkstatt, in der während der Bauzeit der Betrieb weitergeführt werden kann, ist bereits erstellt.
Am WSL–Instituts für Schnee- und Lawinenforschung in Davos Dorf wird der Ersatzneubau Haus D ausgeschrieben.
Die Konstruktion erfolgt in präfabriziertem Holzskelletbau mit Holzbetonverbunddecken und mit aussteifender Bodenplatte und Kern in Ortbeton.
Die bestehende Montagehalle muss während der Bauzeit in Betrieb bleiben und kann erst nach Inbetriebnahme der neuen Montagehalle im Neubau abgebrochen werden.
Eine provisorische Werkstatt, in der während der Bauzeit der Betrieb weitergeführt werden kann, ist bereits erstellt.
Voraussetzungen für nicht dem WTO-Abkommen angehörende Länder: Es werden nur Anbieter aus Ländern zugelassen, die dem WTO-Abkommen angehören.
Verfahrensgrundsätze: Die Auftraggeberin vergibt öffentliche Aufträge für Leistungen in der Schweiz nur an Anbieterinnen und Anbieter, welche die Einhaltung der Arbeitsschutzbestimmungen und der Arbeitsbedingungen für Arbeitnehmer und Arbeitnehmerinnen sowie die Lohngleichheit für Mann und Frau gewährleisten.
Rechtsmittelbelehrung: Gegen diese Publikation kann gemäß Art. 30 BöB innert 20 Tagen seit Eröffnung schriftlich Beschwerde beim Bundesverwaltungsgericht, Postfach, 9023 St. Gallen, erhoben werden. Die Beschwerde ist im Doppel einzureichen und hat die Begehren, deren Begründung mit Angabe der Beweismittel sowie die Unterschrift der beschwerdeführenden Person oder ihrer Vertretung zu enthalten. Eine Kopie der vorliegenden Publikation und vorhandene Beweismittel sind beizulegen.
Nationale Referenz-Publikation: Simap vom 16.12.2020, Dok. 1169989Gewünschter Termin für schriftliche Fragen bis: 22.1.2021.
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: Integrierte Psychiatrie Winterthur - Zürcher Unterland
Country: CH
Contract type: Services
Procedure: Open procedure
CPV classification: 85141200: Services provided by nurses
Submission deadline: 2021-02-01
Award criteria: The most economic tender

Technical requirements: Der Vertrag verlängert sich stillschweigend jeweils um ein weiteres Jahr, jedoch um maximal 4 Jahre (Ende 2029).
Rechtsmittelbelehrung: Gegen diese Ausschreibung kann innert 10 Tagen, von der Publikation an gerechnet, beim Verwaltungsgericht des Kantons Zürich, Postfach, 8090 Zürich, schriftlich Beschwerde eingereicht werden. Die Beschwerdeschrift ist im Doppel einzureichen. Sie muss einen Antrag und dessen Begründung enthalten. Die angefochtene Ausschreibung ist beizulegen. Die angerufenen Beweismittel sind genau zu bezeichnen und, soweit möglich, beizulegen.
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: DGA Council of Europe — Directorate General of Administration
Country: FR
Contract type: Services
Procedure: Restricted procedure
CPV classification: 79710000: Security services
Submission deadline: 2021-02-03
Award criteria: The most economic tender

Technical requirements: La présente procédure est un avis d'appel a candidatures relatif au contrat de sécurité des bâtiments du Conseil de l'Europe. Les candidats présenteront leur dossier de candidature selon les modalités décrites dans la procédure et dans les pièces jointes. Après une analyse détaillée des candidatures, seuls les prestataires jugés eligibles seront retenus pour remettre une offre.
La passation du marché pour le contrat est effectuée conformément aux procédures du COE telles qu'elles sont prévues dans les documents de l'appel d'offres et les instruments juridiques internes du COE en vigueur, à l'exclusion de toute autre procédure d'achat, et notamment l'arrêté 1395 du 20.6.2019 sur les procédures du COE en matière d'achats. Ces documents sont consultables sur le site internet du Conseil de l’Europe http://www.coe.int/fr/web/portal
La publication de cet avis par le COE n'entraîne en aucun cas la renonciation par celui-ci aux privilèges et immunités découlant de l'accord général sur les privilèges et immunités du Conseil de l'Europe et de ses protocoles, et notamment l'article 21 — litiges — de l'accord général.
Les attestations demandées sont à fournir pour chaque membre du groupement. Chaque candidature devra répondre aux trois lots, sous forme de groupement dont le mandataire sera obligatoirement le soumissionnaire au lot 1.
Public procurement notice: Prior Information Notice Without Call For Competition
Published: 2020-12-21
Buyer: West Sussex County Council
Country: UK
Contract type: Works
CPV classification: 45100000: Site preparation work | 45111291 | 45200000: Building and civil engineering work | 45211350 | 45212421
Estimated value: 14500000 GBP

Technical requirements: Broadbridge Heath Council Depot will be declared surplus to WSCC needs at the end of 2020, WSCC are looking to develop the land into a retail park, comprising 2 retail units and 2 restaurant units, subject to planning permission.
Construction of a Retail Park at Broadbridge Heath (subject to planning permission) based on the pre-let of 4 Retail Units and creation of a new access route onto the site through WSCC land.
The Council is seeking suitably experienced contractors that have built-out a retail development park.


Award value: 14500000
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: Pobl Group Ltd
Country: UK
Contract type: Works
Procedure: Open procedure
CPV classification: 34928220 | 44112200 | 44112410 | 44112500 | 44115000
Submission deadline: 2021-02-10
Award criteria: The most economic tender

Technical requirements: Pobl Group wishes to appoint contractors to a framework for planned projects of work for 2 years with the option to extend for two additional 12 months option (2 + 1 + 1). The Framework will be split into ten (10) lots covering East and West of the Group as follows:
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 1a — Whole House Refurbishment West.
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 2a — Flooring Work West.
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 2b — Flooring Works East.
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 3b — Damp Proofing East.
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 5a — Roofing Services West.
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 5b — Roofing Services East.
Pobl Group wishes to appoint up to a maximum of three (3) contractors to Lot 1b — Whole House Refurbishment East.
Note: the authority is using eTenderWales to carry out this procurement process. To obtain further information record your interest on Sell2Wales at https://www.sell2wales.gov.wales/search/search_switch.aspx?ID=106252
The contractor shall ensure that all contracts with subcontractors and suppliers which the contractor intends to procure following the award date, and which the contractor has not, before the date of this contract, already planned to award to a particular subcontractor or supplier, are advertised through the Sell2Wales portal (www.sell2wales.gov.wales) and awarded following a fair, open, transparent and competitive process proportionate to the nature and value of the contract.
Under the terms of this contract the successful supplier(s) will be required to deliver community benefits in support of the authority’s economic and social objectives. Accordingly, contract performance conditions may relate in particular to social and environmental considerations. The community benefits included in this contract are:
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: Spelthorne Borough Council
Country: UK
Contract type: Works
Procedure: Restricted procedure
CPV classification: 45212000: Construction work for leisure buildings | 45212100 | 45212110 | 45212200
Estimated value: 30000000 GBP
Submission deadline: 2021-01-26
Award criteria: The most economic tender

Technical requirements: Spelthorne Borough Council intends to build a new Leisure Centre which will wholeheartedly support the delivery of its leisure and culture strategy. The project aims to create a community sports and fitness destination, key to improving the health and wellbeing of our community. The proposed leisure centre incorporates an 8-lane, 25 m main pool, learner pool, splash pad, spa, a 6-court sports hall, 3 squash courts and multi-use room which combines to create 2 further badminton courts, a café/reception space, soft play, climbing area, 950 m
Other application CPV codes: 45212000 Construction work for buildings relating to leisure, sports, culture lodgings and restaurants; 45212100 Construction work of leisure facilities 45212200 Construction work for sports facilities.

Eligibility requirements: As stated in the procurement documents.

Award value: 30000000
Public procurement notice: Contract Award Notice
Published: 2020-12-21
Buyer: Believe Housing Ltd
Country: UK
Contract type: Works
Procedure: Open procedure
CPV classification: 45111291 | 45211000: Construction work for multi-dwelling buildings | 45211340 | 70111000
Estimated value: 6000000 GBP
Award criteria: Lowest price

Technical requirements: Believe Housing Ltd (believe housing) wish to appoint a contractor for the demolition of existing buildings, design and construction of an older persons’ residential apartment scheme of 1 and 2-bedroom apartments, built over three storeys. The scheme will be designed to meet the increasing need for further elderly persons’ accommodation in Seaham.
Believe Housing Ltd (believe housing) wish to appoint a contractor for the Demolition of existing buildings, design and construction of an older persons’ residential apartment scheme of 1 and 2-bedroom apartments, built over three storeys. The scheme will be designed to meet the increasing need for further elderly persons’ accommodation in Seaham.


Winner: Gus Robinson Developments Ltd
Award value: 6000000
Number of bids: 7
Public procurement notice: Contract Award Notice
Published: 2020-12-21
Buyer: London Borough of Enfield
Country: UK
Contract type: Works
Procedure: Competitive dialogue
CPV classification: 45200000: Building and civil engineering work | 71000000
Estimated value: 135000000 GBP
Award criteria: The most economic tender

Technical requirements: Roboty budowlane w zakresie wznoszenia kompletnych obiektów budowlanych lub ich części oraz roboty w zakresie inżynierii lądowej i wodnej
This notice is for the award of a framework for the delivery of infrastructure works to support the development at Meridian Water. The scope of works is the delivery of strategic utility services and highways, demolition and construction works, earthworks, land remediation and bridges infrastructure to support the new Meridian Water development. The award is to three framework providers.
Meridian Water is a major GBP 6 000 000 000, 25-year London regeneration programme led by Enfield Council, bringing up to 10 000 homes and thousands of jobs to Enfield, north London.
The Council reserve the right not to award call-offs from this framework or to alter the sequence of proposed works required.
This notice is for the award of a framework for the delivery of infrastructure works to support the development at Meridian Water award of a framework for the delivery of main/ strategic utility services and highways and bridges infrastructure to support the development at Meridian Water.
The scope of works is the delivery of strategic utility services and highways, demolition and construction works, earthworks, land remediation and bridges infrastructure to support the new meridian water development. This work will be allocated in phases as detailed in the Memorandum of Information (MOI) within the procurement documents. The scope of the contract is primarily a works contract with an element of design development required.
The Council reserve the right not to award call-offs from this framework or to alter the sequence of the proposed works required. The award is to three framework providers.
Contractor selection to the framework was a lean competitive dialogue procedure conducted in accordance with the Public Contracts Regulations 2015.


Winner: BAM Nuttall Ltd
Award value: 135000000
Number of bids: 3
Public procurement notice: Prior Information Notice Without Call For Competition
Published: 2020-12-21
Buyer: The University of Nottingham
Country: UK
Contract type: Supplies
CPV classification: 48400000 | 48440000 | 48450000 | 48490000 | 72212440

Technical requirements: The University of Nottingham is seeking to replace its extant UK Human Resources (HR), finance, payroll, and procurement systems with modern technology that will enable the University to make a step change in the way it manages its human and financial resources, with knock-on benefits for teaching and research. It will remove the current barriers to 21
The University of Nottingham is a world class teaching and research institution with campuses in the UK, China, and Malaysia. We are home to tens of thousands of students, academics, and staff. Our vision is to be a University without borders, where we embrace the opportunities presented by a changing world, and where ambitious people and a creative culture will enable us to change the world for the better.
We will be undertaking a competition to determine the most economically advantageous tender for the future solution and a partner able to share best practice processes. A competitive dialogue procedure will be employed using a single lot for all requirements with an expectation that a contract will be awarded in Q3 2021. It is anticipated that the contract term will be 10 years.
This PIN is being issued to give potential applicants the opportunity to prepare, as required, ahead of a contract notice being published, and a selection questionnaire being made available in January 2021. The procurement outlined herein is subject to internal approvals; this notice should not be taken as a definitive statement of intent.
Expected total value: GBP 7.5 million in the first year, followed by an annual charge of GBP 2 million.
Although a formal response is not required at this stage, it would help the university to plan subsequent stages if you could indicate any interest to the following contact. This contact can also be used for any general queries:
Public procurement notice: Prior Information Notice Without Call For Competition
Published: 2020-12-21
Buyer: Leidos Supply
Country: UK
Contract type: Supplies
CPV classification: 33000000 | 33100000

Technical requirements: Team Leidos would like to make interested suppliers aware that it intends to tender for a supply and support of a patient warming system, with a view to awarding one or more contracts that will commence during 2021 for a period of up to 4 years. The contract may include training, ancillaries, packaging and consumables.
Please note the equipment will need to be able to operate in a variety of land and maritime environments
Team Leidos wishes to stimulate interest, information and views across the market for the completion of this requirement via this PIN together with other companies whom Leidos believes may be able to provide useful intelligence on our requirement. A draft list of items can be obtained by sending an email request to the contact specified in this bulletin.
This Prior Information Notice is not a means to submit a formal expression of interest in respect of any potential tender. Any resultant requirement will be subject to the EU Public Procurement Regulations and respective advertising action.
Please note all information provided to organizations or individuals that respond to this notice should be treated as confidential and not shared further without express written permission from Leidos Supply Ltd.
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: Queen's University Belfast
Country: UK
Contract type: Supplies
Procedure: Open procedure
CPV classification: 18142000 | 18444100 | 18452000 | 19520000 | 24300000
Submission deadline: 2021-01-15
Award criteria: The most economic tender

Technical requirements: Queen’s University Belfast (Queen’s) require the supply and delivery of laboratory consumables and chemicals. These products will be for the general University and delivery will be required at various sites throughout the campus. Queen’s wish to establish a framework agreement which will be categorised into seven lots as detailed below:
Initial contract period will be for 12 months with the option to extend for a further 36-month period.


Eligibility requirements: https://in-tendhost.co.uk/queensuniversitybelfast/aspx/Home
Public procurement notice: Contract Notice
Published: 2020-12-21
Buyer: Procurement and Logistics Service
Country: UK
Contract type: Supplies
Procedure: Open procedure
CPV classification: 33100000 | 33140000: Medical consumables | 38300000 | 42923000
Estimated value: 713136.62 GBP
Submission deadline: 2021-01-20
Award criteria: Lowest price

Technical requirements: The estimated value per annum is GBP 132 957.40. The estimated value for 4 years would then be GBP 531 829.58. SS17bc — commercial conditions of contract for supplies contracts also allow for up to three further extension periods, each of 6 months. Therefore the total estimated value is GBP 713 136.62. The value is for a 4-year period plus 18 month emergency extension.
In section 1.2, it is stated that this procurement is a joint procedure and contract award is by a Central Purchasing Body. This contract. is not a joint contract, it is a Central Purchasing Body Contract operated by Business Services Organisation Procurement and Logistics. Service on behalf of the participants listed in section 1.1. The contracting authorities will identify the Most Economically Advantageous. Tender(s) (MEAT)on the basis of the ‘lowest price/cost’ submission(s), once full compliance has been demonstrated with all of the. elements of the specification and any other requirements as listed in the Tender Documentation. Details of the evaluation process incorporating price and compliance are provided as part of the Tender Evaluation Methodology and Marking Scheme (TEMMS) SS20b.


Award value: 713136.62
Public procurement notice: Contract Award Notice
Published: 2020-12-21
Buyer: University of Ulster
Country: UK
Contract type: Supplies
Procedure: Open procedure
CPV classification: 48000000 | 72000000
Estimated value: 340000 GBP
Award criteria: Lowest price

Technical requirements: The vision of the project is to develop an enterprise wide CRM system to manage and track a student's journey throughout their University study. This would include aspects of the Student Life Cycle (SLC) such as course management, student support, employability and marketing, international students, student-experience, research and innovation and alumni relationships. The initial focus is on developing the CRM for improving the SLC, with the Business and Community Engagement (BCE) aspects of the CRM to
Via a further competition through the Crown Commerical Services — RM1577.12 G-Cloud Framework. An initial 2-year contract with the potential for the University, acting at its discretion, to extend up to a total further period of 24 months.
An initial 2-year contract with the potential for the University, acting at its discretion, to extend up to a total further period of 24 months.
The estimated total value stated above in section II.1.7) includes the initial 2 year contract period and the option to extend the contract for any periods up to and including 24 months.
The Public Contracts Regulations 2015 provide for aggrieved parties who have been harmed or are at risk of harm by a breach of the rules to take action in the High Court (Northern Ireland).


Winner: Codec-DSS Ltd
Award value: 340000
Number of bids: 2
Public procurement notice: Prior Information Notice With Call For Competition
Published: 2020-12-21
Buyer: capitalEsourcing
Country: UK
Contract type: Services
Procedure: Restricted procedure
CPV classification: 48000000 | 48170000 | 64212700 | 72212700: Utility software programming services | 72227000: Software integration consultancy services
Submission deadline: 2021-01-21
Award criteria: Mixed

Technical requirements: This framework will allow both children and adult social care to procure the Case management as and when needed.
At the heart of this implementation is a fundamental outcome: putting children and families at the heart of the design and supporting them in the most effective way. This is a revolution in case management, moving it from being an administrative tool to taking the role of an enabler of best practice within social work delivery.
Bi-borough Children's Services are also keen to collaborate and jointly design a new approach to case management this exercise will enable potential suppliers to co create the end solution with Bi borough and develop a unique and innovative product for the benefit of the market as whole.
• making as much of the functionality in Lot 1 available to practitioners on the move, this could be through app based technology or equally mobile connectivity back to the core case management system.
• we would look to encourage suppliers bidding for Lot 1 to also consider bidding for this Lot where their product can support the requirements.
• if achievable the provision of off-line records should also be available, for where there isn’t an available network connection.
The detailed requirements are defined within the Lot 2 – Mobile Working Functional Requirements and Lot 2 - Mobile Working Non-functional Requirements documents of this procurement.
The detailed requirements are defined within the ‘Lot 3 – Third Party Collaboration Functional Requirements’ and ‘Lot 3 – Third Party Collaboration Non-functional Requirements’ documents of this procurement.
• use the best of technology to collaborate directly with families and enable this collaboration to support our provision of care. This should also enable a family story style view of records.
• enable transparent and appropriate interaction with records so that children and families can help influence, understand and be part of their own journey.
To register an expression of Interest go via the e-procurement portal CapitalESourcing; https://www.capitalesourcing.com
— click on the project Title 'Children and Adult Case Management Solution Framework' to view details.
https://www.capitalesourcing.com/esop/toolkit/opportunity/opportunityList.do?reset=true&resetstored=true&oppList=CURRENT&_ncp=1608149368835.1236279-1

Eligibility requirements: Listed in the instruction to tender.