Case: Maharashtra State Electricity Board Vs. Sterilite Industries (India)

2. It is stated that the contract for supply of goods was cancelled by the petitioners on April 17, 1989 on the basis that the material which was not supplied by the respondents was procured by the petitioners from other suppliers at a price much higher than what was tendered by the respondents. The petitioners referred to various orders placed by them with different parties. The damages were thus claimed on the basis that the material which was not supplied by the respondents was actually purchased or procured by the petitioners and the damages were computed on the ground of higher price being required to be paid in order to make good the short supply by the respondents. The claim of the petitioners was contested by the respondents on several grounds. 3. The arbitrators raised two issues for consideration, which are as follows :(1) Whether the respondents have committed breach of contract ? or Whether the claimants have committed breach of contract and on account of such breach it became impossible for the respondents to supply the requisite material under the contract ? (2) Whether under the terms of the contract the damages as claimed can be sustained ? 4. On consideration of the relevant material and arguments placed before the arbitrators, per majority, they held that the breach of the contract is committed by the respondents and not by the petitioners. As regards damages claimed by the petitioners, they adverted to clause 14 of the contract to the effect that the purchaser has a right "to purchase upon such terms and in such a manner as he may deem appropriate equipment similar to that terminated" and then "the contractor will be liable to the purchaser for any additional cost for such similar equipment and/or for liquidated damages for delay as defined in Article 22 of the General Conditions until such reasonable time as may be required for the final supply of equipment" and construed the same as providing for (i) that the contractor is liable to reimburse the purchaser the additional cost of similar equipment which the purchaser has purchased, and (ii) that in addition to that or alternatively, the contractor is liable for liquidated damages for delay until such reasonable time as may be required for the supply of equipment and the provision regarding liquidated damages was not attracted in the present case. Clause 14(ii) was thus held to be a special provision with regard to quantum of damages and the quantum is to be determined with reference to the additional cost involved in purchasing the equipment which the contractor had failed to deliver; that in view of this special provision the mode of computation of damages provided for under Section 73 of the Indian Contract Act is not attracted; that, the measure of damages upon a breach of contract for sale of goods is the difference between the contract price and the market price on the date of breach and it is open to the parties to lay down a different rule; that the petitioners had failed to prove that consequent upon the failure of the respondents to supply the material in accordance with the contract, the petitioners had, after the cancellation of the contract, purchased any material in lieu of the material short supplied by the respondents; that the contracts relied upon by the Supreme Court for similar material were already entered into by the petitioners and the supply made thereunder had no relationship with the short supply made by the respondents; that the petitioners had, therefore, failed to prove that they had suffered any damages as contemplated by clause 14 of the contract; that the concept of award of compensation is bound up with loss or damage with results from the breach of contract and where no loss or damages has ensued, there can be no question of awarding compensation; then even under Section 73 of the Indian Contract Act where a claim for damages on the ground of breach of contract is made by a party, the party claiming damages is under an obligation to prove the loss; that the claimants in the instant case had failed to prove that they had suffered any loss. On this basis, the arbitrators held that the petitioners were not entitled to invoke the provisions of Section 73 of the Indian Contract Act and they had failed to prove that any additional purchases were made to make up for the short supply resulting from the breach of contract by the respondents and even otherwise, the petitioners had failed to prove that they had suffered any damages and were, therefore, not entitled to any damages. Accordingly, the claim made by the petitioners was dismissed. 5. The minority view expressed by another arbitrator is that clause 14(ii) of the contract enables the purchaser the right to purchase upon such terms and manner as he may deem appropriate and that gives only an additional option without affecting the rights arising under general Law and, therefore, he was of the view that the claim should be allowed. 6. On the award being sought to be made the decree of the Court, objections were raised in the proceedings before a learned Single Judge of the High Court, who, on examination adverted to the award and, in particular, to the scope of clause 14(ii) of the contract entered into between the parties. The learned Single Judge is of the view that if the arbitrators have given reasons in support of their decision, it would be open to the court to set aside the order if it finds that the error of law has been committed by the arbitrators, though reasonableness thereof cannot be challenged. He is influenced by the fact that what is found in the award on the aspect of loss and quantum of damages against the petitioners is pure finding of fact based on appreciation of evidence and, therefore, could not be examined by the Court. He is further of the view that where loss in terms of money can be determined, the party claiming compensation must prove the loss suffered by it in order to attract Section 73 of the Indian Contract Act; that the concept of award of compensation is bound up with the loss or damage that results from the breach of contract and where no loss or damage has ensued, there can be no question of awarding compensation; that the majority of the arbitrators have said that the petitioners had failed to prove that they had suffered any loss and, therefore, are not entitled to claim any damages and thus the claim had to be rejected. The learned Single Judge took the view that an award can only be set aside if there is an error of fact or an error of law and unless such error is apparent on the face of the record, the objections cannot be sustained and, hence he overruled the objections holding that the award is unassailable in proceedings under Section 30 of the Arbitration Act. 7. Appeals were filed against this order of the learned Single Judge on the Letters Patent side and a Division Bench of the High Court reiterated the view taken by the learned Single Judge after reappraisal of the facts, the award made by the arbitrators and the contentions raised in the appeals. It is against this order of the Division Bench, these special leave petitions are filed.

Court's reasoning:
12. In the light of this enunciation of law, we are of the view that unless the error of law sought to be pointed out by the learned counsel for the petitioners in the instant case is patent on the face of the award neither the High Court nor this Court can interfere with the award. The exercise to be done by examining clause 14(ii) of the contract entered into between the parties, construing the same properly and thereafter applying the law to it to come to a conclusion one way or the other, is too involved a process and it cannot be stated that such an error is apparent or patent on the face of the award. Whether under the context of the terms and conditions of a contract, a stipulation in the form and nature of clause 14(ii) operates as a special provision to the exclusion of Section 73 of the Indian Contract Act is a matter of appreciation of facts in a case, and when the decision thereon is not patently absurd or wholly unreasonable, there is no scope for interference by courts dealing with a challenge to the award. Therefore, we think, the view taken by the High Court in this matter is correct and calls for no interference. 13. If as construed by the arbitrators that clause 14(ii) excludes applicability of Section 73 of the Indian Contract Act and the proposition of law stated by the arbitrators is correct, then Section 73 is not attracted to the case.