Exhibit 10.13
 
[f8k0210ex10xiii_envision20.jpg]

 
 
STANDARD SHORT FORM AGREEMENT BETWEEN
PROJECT OWNER AND SYSTEM SUPPLIER

 
This Agreement is made this 6 day of JULY in the year 2009, by and between the

 

 PROJECT OWNER: Team Solar, Inc.  
5000 Bailey Loop
McCIellan CA 95652

 
and the SYSTEM SUPPLIER:
 
ENVISION SOLAR INTERNATIONAL, INC.
4225 Executive Square, Suite
1000 LaJolla, CA 92037
 
for services in connection with the WORK:
 
Solar Design & Engineering; PV Support Foundations; PV Support Steel Detailing,
Fabrication, & Erection; Prefmished Tapered Metal Beam Wraps; and PV Module
Installation.
 
for the following PROJECT: California State University - Bakersfield
 
located at the PROJECT SITE: Bakersfield, CA
 
and for which the PROJECT NUMBER is: CA-08-0041
 
 
1

--------------------------------------------------------------------------------

 
1.   THE WORK System Supplier shall perform all required design, engineering,
construction administration and management services and furnish and install all
required material and equipment to complete the scope of work. The System
Supplier shall use its best efforts to perform the Work in an expeditious manner
consistent the direction of the Project Owner and the Contract Documents
applicable to System Supplier's scope of work. System Supplier shall provide all
labor, equipment and services necessary to complete the Work, as described in
Exhibit A, all of which shall be provided in full accord with the direction of
the Project Owner, or when applicable, reasonably inferable from the Contract
Documents as being necessary to produce the indicated results. All on-site
construction work shall be performed by a licensed California Contractor.
 
2.   CONTRACT PRICE As full compensation for performance by System Supplier of
the Work, Project Owner shall pay System Supplier the lump sum price of one
million, three hundred thirty six thousand, four hundred eighty four dollars
($1,336,484.00). The lump sum price is hereinafter referred to as the Contract
Price, which shall be subject to increase or decrease as provided in this
Agreement.
 
3.   EXHIBITS The following Exhibits are incorporated by reference and made part
of this Agreement:
 

 
l.
Exhibit 'A' -
Contract Documents
 
2.
Exhibit 'B' -
Scope of Work
 
3.
Exhibit 'C' -
Progress Schedule, Milestones, & Liquidated Damages
 
4.
Exhibit 'D' -
Payment Form with Schedule of Values
 
5.
Exhibit 'E' -
Insurance Requirements
 
6.
Exhibit 'F' -
Interim and Final Lien Wavers
 
7.
Exhibit 'G' -
Add Alternates - NOT USED
 
8.
Exhibit 'H' -
Unit Prices-NOT USED
 
9.
Exhibit 'T' -
Change Order Form
 
10.
Exhibit 'T'-
Not Used
 
11.
Exhibit 'K'-
List of Owner Furnished Material & Equipment
 
12.
Exhibit 'L'-
Warrantee Requirements

 
4.    SYSTEM SUPPLIER'S RESPONSIBILITIES It is understood and agreed that the
System Supplier will provide direction to the designated representative of the
System Supplier. The System Supplier shall be responsible for supervision and
coordination of the Work, including the construction means, methods, techniques,
sequences and procedures utilized, unless the Contract Documents give other
specific instructions.
 
4.1 All permits and fees shall be the responsibility of the Project Owner
pursuant to this Agreement, except as detailed in Exhibit B.
 
4.2 The Project Owner shall be responsible for all applicable taxes, including
the Work provided by System Supplier.
 
4.3 In the event that Project Owner elects to perform work at the Project Site
directly or by others retained by Project Owner, System Supplier and Project
Owner shall coordinate the activities of all forces at the Project Site and
shall agree upon fair and reasonable schedules and operational procedures for
Project Site activities. Project Owner shall require each separate contractor to
cooperate with System Supplier and assist with the coordination of activities
and the review of construction schedules and operations. The Contract Price and
Contract Time shall be equitably adjusted, as mutually agreed by the parties,
for changes made necessaiy by the coordination of construction activities, and
the construction schedule shall be revised accordingly.
 
4.4 In order to facilitate its responsibilities for completion of the Work in
accordance with and as reasonably inferable from the Contract Documents, prior
to commencing the Work, System Supplier shall examine and compare the drawings
and specifications with information furnished by Project Owner; relevant field
measurements made by System Supplier; and any visible conditions at the Project
Site affecting the Work. Notwithstanding the foregoing, System Supplier shall
have no responsibility for the design errors, omissions, or inconsistencies of
Project Owner, Project Company or any other 3rd parties for whom System Supplier
is not liable.
 
2

--------------------------------------------------------------------------------

 
4,5 WARRANTY
 
4.5.1 The Work shall be executed in accordance with the Contract Documents in a
workmanlike manner. In the event the System Supplier's Work is modified to
include work beyond a time & material basis, the System Supplier warrants that
all materials and equipment shall be new, of good quality, in conformance with
the Contract Documents, and free from defective workmanship and materials. In
such a case, the System Supplier's warranty does not include remedies for
defects or damages caused by normal wear and tear during normal usage, use for a
purpose for which the Project was not intended, improper or insufficient
maintenance, modifications performed by Project Owner or others retained by
Project Owner, or abuse. System Suppliers' warranty shall commence upon Final
Acceptance of the Work by the Project Owner and continue for a period of 1 year
thereafter. No other warranties, express nor implied, are provided by System
Supplier; provided, System Supplier hereby assigns to Project Owner all specific
written warranties provided by System Suppliers, vendors, and manufacturers and
all such specific warranties shall continue as noted therein.
 
4.6 SAFETY As between Project Owner and System Supplier, System Supplier shall
have overall responsibility for safety precautions and programs in the
performance of the Work by System Supplier and its lower tiers, except that
System Supplier's System Suppliers shall also be responsible for the safety of
persons or property in the performance of their work, and for compliance with
the provisions of applicable laws and regulations. System Supplier shall seek to
avoid injury, loss or damage to persons or property by taking reasonable steps
to protect its employees and other persons at the Project Site; materials and
equipment stored at on-site or off-site locations for use in the Work; and
property located at the site and adjacent to Work areas, whether or not the
property is part of the Work.
 
4.7 HAZARDOUS MATERIALS A Hazardous Material is any substance or material
identified now or in the future as hazardous under any federal, state or local
law or regulation, or any other substance or material which may be considered
hazardous or otherwise subject to statutory or regulatory requirement governing
handling, disposal and/or clean-up. System Supplier shall not be obligated to
commence or continue work until any Hazardous Material discovered at the Project
Site has been removed, or rendered or determined to be harmless by Project Owner
as certified by an independent testing laboratory and approved by the
appropriate government agency. If System Supplier incurs additional costs and/or
is delayed due to the presence or remediation of Hazardous Material, System
Supplier shall be entitled to an equitable adjustment in the Contract Price
and/or the Contract Time.
 
4.8 MATERIALS BROUGHT TO THE WORKSITE System Supplier shall be responsible for
the proper delivery, handling, application, storage, removal and disposal of all
materials and substances brought to the Project Site by System Supplier in
accordance with the Contract Documents and used or consumed in the performance
of the Work.
 
4.9 SUBMITTALS In the event that the System Supplier's Work is expanded, the
System Supplier shall submit to Project Owner for review and approval all shop
drawings, samples, product data and similar submittals as may be required by
either this Agreement or the Contract Documents. System Supplier shall be
responsible to Project Owner for the accuracy and conformity of its submittals
to the Contract Documents. System Supplier shall prepare and deliver its
submittals to Project Owner in a manner consistent with the Progress Schedule of
the Work and in such time and sequence so as not to delay the performance of the
Work or the work of Project Owner and others retained by Project Owner. When
System Supplier delivers its submittals to Project Owner, System Supplier shall
identify in writing for each submittal all changes, deviations or substitutions
from either the requirements of this Agreement or the Contract Documents. The
approval of any System Supplier submittal shall not be deemed to authorize
deviations, substitutions or changes in the requirements of the Contact
Documents unless express written approval is obtained from Project Owner
specifically authorizing such deviation, substitution or change. Further,
Project Owner shall not make any change, deviation or substitution through the
submittal process without specifically identifying and authorizing such
deviation to System Supplier. Project Owner shall be responsible for review and
approval of submittals with reasonable promptness (3 business days) to avoid
causing delay. System Supplier shall perform all Work strictly in accordance
with approved submittals. Project Owner's approval does not relieve System
Supplier from responsibility for Defective Work resulting from errors or
omissions of any kind within the approved submittals.
 
3

--------------------------------------------------------------------------------

 
4.10 SITE CONDITIONS If the conditions at the Project Site are (a) subsurface or
other physical conditions which are materially different from those indicated in
the Contract Documents, or (b) unusual or unknown physical conditions which are
materially different from conditions ordinarily encountered and generally
recognized as inherent in Work provided for in the Contract Documents, System
Supplier shall stop Work and give written notice of the condition to Project
Owner as soon as possible upon recognition of the condition. System Supplier
shall not be required to perform any work relating to the unknown condition
without the written mutual agreement of the parties. Any change in the Contract
Price and/or Contract Time as a result of the unknown condition shall be made by
Change Order.
 
4.11 CUTTING, FITTING AND PATCHING System Supplier shall perform cutting,
fitting and patching necessary to coordinate the various parts of the Work and
to prepare its Work for the work of Project Owner or others retained by Project
Owner.
 
4.12 CLEANING UP System Supplier shall regularly remove debris and waste
materials at the Project Site resulting from System Supplier's Work. Prior to
discontinuing Work in an area, System Supplier shall clean the area and remove
all rubbish and its construction equipment, tools, machinery, waste and surplus
materials. System Supplier shall minimize and confine dust and debris resulting
from construction activities. At the completion of the Work, System Supplier
shall remove and dispose in a lawful manner from the Project Site all
construction equipment, tools, surplus materials, waste materials (excluding
Hazardous Materials) and debris,
 
5.            PROJECT OWNER'S RESPONSIBILITIES Any information or services to be
provided by Project Owner shall be provided in a timely manner (two (2) business
days) so as not to delay the Work.
 
5.1WORKSITE INFORMATION Project Owner shall provide at Project Owner's expense
and with reasonable promptness the following;
 
.1 information describing the physical characteristics of the site, including
surveys, site evaluations, legal descriptions, data or drawings depicting
existing conditions;
.2 subsurface reports may be provided by Project Owner; it is understood and
agreed that such subsurface reports are provided for information only, Project
Owner makes no warranty as to the accuracy and reliability of such reports; and
.3 any other information or services requested in writing by System Supplier
that are relevant to System Supplier's performance of the Work and under Project
Owner's control.
 
5.2 EVIDENCE OF ABILITY TO PAY Upon written request by the System Supplier the
Project Owner shall
provide to System Supplier reasonable evidence of Project Owner's ability to pay
System Supplier for the Work
(i.e. tax equity financing, bank financing, other).
 
6.   SUBCONTRACTS Work not performed by System Supplier with its own forces
shall be performed by System Suppliers. System Supplier agrees to bind eveiy
System Supplier and material supplier (and require every System Supplier to so
bind its System Suppliers and material suppliers) to all the provisions of this
Agreement and the Contract Documents as they apply to the System Supplier's and
material supplier's portions of the Work.

 
7.   CONTRACT TIME
 
7.1 DATE OF COMMENCEMENT Unless otherwise agreed in writing the date of this
agreement shall serve as the Date of Commencement of Work, unless, as to those
permits which are not the responsibility of System Supplier, Project Owner has
not obtained all permits and approvals necessary for System Supplier to commence
the Work.
 
7.2 TIME The Contract Time shall be measured from the date of commencement. The
Contractor shall achieve Substantial Completion of the entire Work not later
than 79 calendar days from the date of commencement of construction, subject to
adjustments of this Contract Time as provided in the Contract Documents. This
shall also be in accordance with the schedule and required interim milestones as
indicated in Exhibit 'C - Progress Schedule, Milestones & Liquidated Damages,
attached to this contract.
 
8.   SCHEDULE OF THE WORK: See Exhibit C.
 

9.DELAYS AND EXTENSIONS OF TIME: If the System Supplier is delayed at any time
in the commencement or progress of the Work by an act or neglect of the Project
Owner or any 3rd party for whom System Supplier is not responsible (i.e., other
than System Supplier's System Suppliers, suppliers, agents, employees), or by
changes ordered in the Work, or by labor disputes, fire, unusual delay in
deliveries, unavoidable casualties or other causes beyond the System Supplier's
control, or by delay authorized by the Project Owner, then the Contract Time and
Contract Price shall be equitably adjusted. The Project Owners determination of
merit and notice to the System Supplier on Claims for extension of time shall
not be unreasonably withheld by Project Owner.
 
4

--------------------------------------------------------------------------------

 
10.          ALLOWANCES: Not Applicable.
 
11.          CHANGES

11.1 System Supplier may request and/or Project Owner may order changes in the
Work or the timing or sequencing of performance of the Work that impacts the
Contract Price or the Contract Time. All such changes in the Work that affect
Contract Time or Contract Price shall be formalized in a Change Order, to be
approved by Project Owner.
 
11.2 Project Owner and System Supplier shall negotiate in good faith an
appropriate adjustment to the Contract Price and/or the Contract Time and shall
conclude these negotiations as expeditiously as possible. Acceptance of the
Change Order and any adjustment in the Contract Price and/or Contract Time shall
not be unreasonably withheld.
 
11.3 COST OR CREDIT DETERMINATION
 
11.2.3.1 An increase or decrease in the Contract Price and/or the Contract Time
resulting from a change in the Work shall be determined by one or more of the
following methods:
 
.1 unit prices set forth in this Agreement or as subsequently agreed;
.2 a mutually accepted, itemized lump sum;
.3 costs calculated on a basis agreed upon by Project Owner and System Supplier
plus a fee (either a lump sum or a fee based on a percentage of cost) to which
they agree; or .4 by the method provided below:
 
11.4 It is understood and agreed that only the net amount of any Change Order
will be subject to the System Supplier Fee of fifteen (15) percent. System
Supplier Fee will be all inclusive of all direct and indirect field overhead and
supervision; all corporate overhead; all insurances; all material markups; and
all profit.
 
11.5 PERFORMANCE OF CHANGED WORK System Supplier shall not be obligated to
perform Changed Work until a Change Order has been executed by Project Owner and
System Supplier.
 
12.          PAYMENT
 
12.1 INITIAL PROGRESS PAYMENT - Upon execution of this Agreement, System
Supplier shall submit to Project Owner an application for payment covering
initial design costs. Project Owner shall pay the amount otherwise due on any
approved payment application, less any amounts as set forth below, no later than
seven (7) days after System Supplier has submitted a complete and accurate
payment application.
 
12.2 PROGRESS PAYMENTS - System Supplier shall submit to Project Owner and, if
directed, a monthly application for payment no later than the 25th day of the
calendar month for the preceding thirty (30) days. System Supplier's
applications for payment shall be itemized and supported by System Supplier's
schedule of values and any other substantiating data as required by this
Agreement, Payment applications shall include payment requests on account of
properly authorized Change Orders. Project Owner shall pay the amount otherwise
due on any approved payment application, less any amounts as set forth below, no
later than twenty (20) days after System Supplier has submitted a complete and
accurate payment application. Progress Payments will be accelerated should
Project Owner require expedited procurement of materials.
 
12.3RETAINAGE - For all System Supplier Work not performed on a time & material
basis, the Project Owner shall retain five (5) percent of the approved monies
due System Supplier until the accepted Substantial Completion of System
Supplier's Work, and thereafter only withhold such amount equating to a
reasonable estimate of the cost to complete remaining punch-list items.
 
12.4 FAILURE TO PAY - If the Project Owner does not pay the System Supplier as
required herein, then the System Supplier may, upon seven additional days'
written notice to the Project Owner, suspend the Work until payment of the
amount owing has been received. The Contract Time shall be extended
appropriately and the Contract Price shall be increased by the amount of the
System Supplier's reasonable costs of shut-down, delay and start-up, plus
interest as provided for in the Contract Documents.
 
5

--------------------------------------------------------------------------------

 
12.5 Reserved
 
12.6 FINAL COMPLETION When final completion has been achieved, inclusive of the
satisfactory completion of System Supplier's punchlist, and the acceptance of
all applicable warrant)', and operation and maintenance documentation, as
applicable, the System Supplier shall prepare for Project Owner's acceptance a
final report stating that to the best of System Supplier's knowledge, and based
on Project Owner's inspections, the Work has reached final completion in
accordance with the Contract Documents. Upon achieving this final Completion,
The Project Owner shall promptly release for payment all remaining amounts due
the System Supplier.
 
13.          OWNERSHIP OF DOCUMENTS - OWNERSHIP OF ARCHITECTURAL DESIGNS
 
13.1 PROPERTY OF SYSTEM SUPPLIER. All Design Documents, including, without
limitation, and designs, building designs or other depictions underlying or
shown in them, shall be deemed the sole and exclusive property of System
Supplier and ownership thereof is irrevocably vested in System Supplier, whether
or not the Project is constructed.
 
13.2 INTETLLECTUAL PROPERTY/ASSIGNMENT OF RIGHTS. All Intellectual Property
Rights in the Design Documents, including any designs, building designs or other
depictions underlying or shown in them are the property of System Supplier.
System Supplier shall own all Intellectual Property Rights and any other
tangible and/or intangible property rights in or associated with the Design
Documents. No transfer and assignment will be effective for the entire duration
of such Intellectual Property Rights and other rights thereto and include, but
not be limited to, all rights including rights in related plans, specifications,
documentation, derivative works and moral rights.

 
13.3 USE BY PROJECT OWNER. Without limitation to the other provisions of this
Section 13, Project Owner shall have the right to use the Design Documents for
the construction, use, occupancy or maintenance of the Project, including,
without limitation, future additions, alterations, or repairs to the Project.

 
13.4 SYSTEM SUPPLIER'S WARRANTY. System Supplier represents and warrants that
the Design Documents, and the use of the Design Documents in the ordinaiy
course, are free of any claim of infringement and will not violate any right of
any third party, including any Intellectual Property Right.

 
13.5 INSPECTION BY PROJECT OWNER. Project Owner shall have the right at any time
or times, upon prior written request to System Supplier, to review the status
and condition of the Design Documents while in development or during
construction and to request that copies thereof be provided to Project Owner,
with the cost of such copies reimbursed to System Supplier as a Reimbursable
Expense.

 
14.          INDEMNITY
 
14.1 To the fullest extent permitted by law, System Supplier shall defend,
indemnify and hold Project Owner, Project Owner's officers, directors, members,
consultants, agents and employees and the Host and Project Company harmless from
all claims for bodily injury and property damage, other than to the Work itself
and other property insured under Exhibit E, that may arise from the performance
of the Work to the extent of the negligence attributed to such acts or omissions
by System Supplier, sub-contractors or anyone employed directly or indirectly by
any of them or by anyone for whose acts any of them may be liable. System
Supplier shall not be required to defend, indemnify or hold harmless Project
Owner or Project Company or others retained by Project Owner for any acts,
omissions or negligence of Project Owner or Project Company or others retained
by any other party.
 
14.2 To the fullest extent permitted by law, Project Owner shall defend,
indemnify and hold harmless System Supplier, its officers, directors or members,
System Suppliers or anyone employed directly or indirectly by any of them or
anyone for whose acts any of them may be liable from all claims for bodily
injury and property damage, that may arise from the performance of work by
Project Owner or Project Company to the extent of the negligence attributed to
such acts or omissions by these parties.
 
15. MUTUAL WAIVER OF CONSEQUENTIAL DAMAGES Project Owner and System Supplier
agree to waive all claims against each other for any consequential damages that
may arise out of or relate to this Agreement. Project Owner agrees to waive such
damages including but not limited to Project Owner's loss of use of the Project,
any rental expenses incurred, loss of income, profit or financing related to the
Project, as well as the loss of business, loss of financing, principal office
overhead and expenses, loss of profits not related to this Project, or loss of
reputation. System Supplier agrees to waive damages including but not limited to
loss of business, loss of financing, principal office overhead and expenses,
loss of profits not related to this Project, loss of bonding capacity or loss of
reputation. This Paragraph shall not be construed to preclude contractual
provisions for liquidated damages when such provisions relate to direct damages
only. The provisions of this Paragraph shall also apply to the termination of
this Agreement and shall survive such termination.
 
6

--------------------------------------------------------------------------------

 

15. 
MUTUAL WAIVER OF CONSEQUENTIAL DAMAGESProject Owner and System Supplier agree to
waive all claims against each other for any consequential damages that may arise
out of or relate to this Agreement. Project Owner agrees to waive such damages
including but not limited to Project Owner's loss of use of the Project, any
rental expenses incurred, loss of income, profit or financing related to the
Project, as well as the loss of business, loss of financing, principal office
overhead and expenses, loss of profits not related to this Project, or loss of
reputation. System Supplier agrees to waive damages including but not limited to
loss of business, loss of financing, principal office overhead and expenses,
loss of profits not related to this Project, loss of bonding capacity or loss of
reputation. This Paragraph shall not be construed to preclude contractual
provisions for liquidated damages when such provisions relate to direct damages
only. The provisions of this Paragraph shall also apply to the termination of
this Agreement and shall survive such termination.
 

16.          NOTICE TO CURE AND TERMINATION

16.1 TERMINATION BY OWNER If, within seven (7) days of receipt of a notice to
cure pursuant to Paragraph 16.1, System Supplier fails to commence and
satisfactorily continue correction of the default set forth in the notice to
cure, Project Owner may notify System Supplier that it intends to terminate this
Agreement for default absent appropriate corrective action within fourteen (14)
additional days. After the expiration of the additional seven (7) day period,
Project Owner may terminate this Agreement by written notice absent appropriate
corrective action. Termination for default is in addition to any other remedies
available to Project Owner under Paragraph 17. If Project Owner's costs arising
out of System Supplier's failure to cure, including the cost of completing the
Work and reasonable attorney fees, exceed the unpaid Contract Price, System
Supplier shall be liable to Project Owner for such excess costs. If Project
Owner's costs are less than the unpaid Contract Price, Project Owner shall pay
the difference to System Supplier. In the event Project Owner exercises its
rights under this Paragraph, upon the request of System Supplier, Project Owner
shall furnish to System Supplier a detailed accounting of the costs incurred by
Project Owner.
 
16.2 TERMINATION BY PROJECT OWNER Upon seven (7) days' written notice to Project
Owner, System Supplier may terminate this Agreement if the Work:
 
(a)  has been stopped fr a sixty (60) day period through no fault of System
Supplier for any of thefollowing reasons:

 

.1 under court order or order of other governmental authorities having
jurisdiction;
 
.2 as a result of the declaration of a national emergency or other governmental
act during which, through no act or fault of System Supplier, materials are not
available; or
 

  (b) If the Project Owner fails within a sixty (60) day period to pay the
System Supplier amounts due under the contracts as provided in Section 12.2 and
the System Supplier has provided the Project Owner seven (7) days' written
notice to Project Owner.

 
16.3 TERMINATION FOR CONVENIENCE The Project Owner may, at any time, terminate
this Agreement for the Project Owner's convenience and without cause. In case of
such termination for the Project Owner's convenience, the System Supplier shall
be entitled to receive payment for the Subcontract Work executed, and costs
incurred by reason of such termination, along with reasonable overhead and
profit on the Subcontract Work not performed. Upon receipt of written notice
from the Project Owner of such termination for the Project Owner's convenience
the System Supplier shall:
 
.1 cease operations as directed by the Project Owner in the notice;
 
.2 take actions necessaiy, or as the Project Owner may direct for the protection
/ preservation of the Work;

 
.3 except for the Work directed to be performed prior to the e ffective date of
termination stated in the notice, terminate all existing Sub-subcontracts and
purchase orders and enter into no further Sub-subcontract and/or purchase
orders.

7

--------------------------------------------------------------------------------

 
 
 
 
17. 
ASSIGNMENT Neither Project Owner nor System Supplier shall assign its interest
in this Agreement without the written consent of the other except as to the
assignment of proceeds. The terms and conditions of this Agreement shall be
binding upon both parties, their partners, successors, assigns and legal
representatives. Neither party to this Agreement shall assign the Agreement as a
whole without written consent of the other.

 
18.        GOVERNING LAW This Agreement shall be governed by the law in effect
at the location of the Project.
 
19  
JOINT DRAFTING The parties expressly agree that this Agreement was jointly
drafted, and that they both had opportunity to negotiate terms and to obtain
assistance of counsel in reviewing terms prior to execution. This Agreement
shall be construed neither against nor in favor of either party, but shall be
construed in a neutral manner.

 
20  
DISPUTE RESOLUTION In the event of a dispute, controversy, or claim arising out
of or relating to this Agreement, the System Supplier and Subcontractor ("the
Parties") shall confer and attempt to resolve such matter informally. If such
dispute or claim cannot be resolved in this manner, then the dispute or claim
shall be referred first to the Parties' executive officers for their review and
resolution. Claims not resolved by other means shall be decided by arbitration
which, unless the parties mutually agree otherwise, shall be in accordance with
the Construction Industry Arbitration Rules of the American Arbitration
Association currently in effect. The demand for arbitration shall be filed in
writing with the other party to the Contract and with the American Arbitration
Association. Any arbitration shall be conducted by a mutually agreed Arbitrator.
The award rendered by the arbitrator shall be final and binding on the Parties
and shall be deemed enforceable in any court having jurisdiction thereof and of
the Parties. The arbitration shall be heard by one arbitrator, who shall have
experience in the general subject matter to which the dispute relates, for
claims in excess of $250,000 a panel of multiple Arbitrators shall be used. The
shall take place in the state where the Work has been performed or in a mutually
agreed location. The cost of the arbitration shall be borne equally by the
Parties. If either Party becomes involved in arbitration or litigation arising
from this Agreement, each Party will be responsible for its own legal and
attorney's fees.

 

 
PROJECT OWNER:
 

BY: /s/ William Morrow   ATTEST:     William Morrow                 Director,
Construction                   PRINT NAME                     PRINT TITLE      
         

 
 
SYSTEM SUPPLIER
 

BY: /s/ William Adelson   ATTEST: /s/ Joanna Tan   William Adelson              
President     Joanna Tan                        CFO, COO             PRINT
NAME                   PRINT TITLE      

 
 
                                
 
 
 
 
 
 
8

--------------------------------------------------------------------------------

 
EXHIBIT A - CONTRACT DOCUMENTS
 

 

 

Project Name:  CSU - Bakersfield - Parking Lot E Canopy     Project Number:
 CA-08-0041 Project Location: 9001 Stockdale Hwy
Bakersfield CA
    Project Description: Solar design and structural engineering: PV foundation
supports; PV support steel detailing, fabrication & erection, PV module
Installation.

 
 

  Sheet   Title   Author   Date                   T   Title Page  
SunEdison/ Envision
  6/26/09   A.l     Site Plan   SunEdison/ Envision   6/26/09   A.2    Demo Plan
  SunEdison/ Envision   6/26/09   A.3    Site Elevations  
SunEdison/ Envision
  6/26/09   A.4     Large Array plans and elevations   SunEdison/ Envision  
6/26/09   A.5      Medium Array plans and elevations   SunEdison/ Envision  
6/26/09   A.6      Small Array plans and elevations   SunEdison/ Envison  
6/26/09   A.7    Reflected Ceiling plans   SunEdison/ Envision   6/26/09   A.8 
  Reflected Ceiling plans   SunEdison/ Envision   6/26/09   A.9    Sections  
SunEdison/ Envision   6/26/09   A.10   Details   SunEdison/ Envision   6/26/09  
S.1   Structural notes and plans   Orie's/SunEdison/ Envision   6/26/09   S.2  
Structural elevations and details   Orie's/SunEdison/ Envision   6/26/09   S.3  
Inverter equipment pad and anchorage   Orie's/SunEdison/ Envision   6/26/09  
S.4   Inverter equipment pad details   Orie's/SunEdison/ Envision   6/26/09

 
 
1

--------------------------------------------------------------------------------

 

EXHIBIT B - SCOPE OF WORK

A.   General
 
 
a.
System Supplier shall obtain and maintain all permits and licenses required to
perform and complete its work, unless otherwise indicated.

 

 
b.
System Supplier is responsible for generation of the Construction sets of the
Contract Documents. The System Supplier is responsible for reproduction or
procurement of any additional sets required to perform the work and shall
provide any required sets to Project Owner upon request. All printing costs are
a reimbursable expense.

 

 
c.
System Supplier shall provide to Project Owner all required Shop Drawings,
Submittals, Samples, As-Builds, Operating Manuals, overstock materials, and all
warranties required by the Contract Documents.

 
  d.      All Requests for Information must be in writing to and from Project
Owner and System Supplier.
 
 
e.
System Supplier shall provide Daily Work Reports to the Project Owner's Project
Superintendent for each day System Supplier is working on site.

 

 
f.
System Supplier shall provide required Quality Control and Completion
documentation and checklists to the Project Owner's Project Superintendent on a
regular basis.

 

  g.     System Supplier shall provide a list of all materials with lead-times
over two (2) weeks.
 
 
h.
Project Owner shall be responsible for all material stocking and storage, which
includes Project Owner supplied material and/or equipment.

 

 
i.
Project Owner shall provide and be responsible for any storage containers and or
field office trailers required to complete their work, in locations determined
by Project Owner.

 
   j.      If applicable, System Supplier shall provide quantity survey for
Project Owner provided materials.
 
  k.      System Supplier shall coordinate and install all Project Owner
provided items per the Contract Documents, as pertaining to System Supplier's
work.

 
  l.      Parking is the responsibility of System Supplier; coordinated with
Project Owner's Project Superintendent.

 m.     Coordinate and manage inspections by the local building department,
utility field engineers, project company consultants, all as may be required, in
order to obtain all final approvals.

 
2

--------------------------------------------------------------------------------

 

B.   Safety
 

 
A.
All of the System Supplier's work shall comply with all local, State and Federal
building codes, laws and regulations.
 
 
B.
System Supplier shall adhere to all current safety laws including, but not
limited to Local, State, and Federal OSHA regulations, and to Project Owner's
safety standards.
 
  C.
Hard hats are required on this project by ALL persons, at ALL times, and in ALL
areas.
 
 
D.
System Supplier must keep records on site of daily and weekly safety meeting and
will provide copies to Project Owner upon request.
 
 
E.
System Supplier must keep records onsite of individuals who are trained and
qualified to operate equipment on the jobs ite.
 
 
F.
System Supplier must contact USA Utility or the appropriate company to identify
all underground lines prior to digging. Any disconnections of service will be
the responsibility of the System Supplier.
 
  G. 
 Provide required Certificate of Insurance (with noted Additional Insureds)
prior to mobilization on the Project.
 
 
H.
System Supplier to have a designated Superintendent on site at all times while
installation activities are being conducted so as to be a single
point-of-contact for both Project Owner and the Host Company. Superintendent
will provide Project Owner with a 24-hour contact person and the individual must
be able to communicate in English.
 
 
I.
Project Owner is responsible to provide and or install all required safety
equipment, rails, protection or other devices and or equipment necessary to
complete the work.
 
  J. 
Project Owner is responsible for security to protect any materials staged on the
ground during non working hours.
 
  K.
The System Supplier shall comply with all security and safety requirements and
regulation of the Host Company.
 
  L.
The following Safety Documents will be provided to the Project Owner's
Construction for review and approval prior to issuance of a Notice to Proceed.
         
a.    System Suppliers General Safety Plan
 
   
b.    Site Specific Safety Plan
 
   
c.    Site Specific Risk Assessment
 
    d.    Site Specific Emergency Action Plan

 
C.   Design Scope
 
A.
Furnish all required design documents including but not limited to Drawings,
Specifications, Design Manuals, Design Standards, necessary to permit, and
construct the Tee Structures, Support Foundations, PV Support Steel and PV
Module Installation in compliance with all local, state, and national codes and
jurisdictional requirements & regulations.    
B.
Due Diligence Documents       a.
Project Owner shall provide Facility As-Built drawings to System Supplier.
System Supplier is responsible for verification and coordination of this
information with their design.

 
3

--------------------------------------------------------------------------------

 

 

  b. Provide all Site Evaluation and Preliminary Approval deliverables.        
c.  Notate any host-customer considerations and requirements known prior to
design/technical specification.       C. Provide required preliminary design
documents to evaluate initial product and system specifications for review by
Project owner and/or the Host Company, provide follow up corrective action items
as necessary.      
D.
 
Provide permit submittal ready, approved by licensed PE for each discipline
required, prior to permit submittal for final design review.
 
E.
 
Comply with all local Utility, AHJ, and National code agencies as appropriate -
obtain in writing, any code variances approved by authorized agencies.
 
F.  
Provide updated design drawings, per approved change orders, during construction
as appropriate.
 
G.   
Provide As-Built drawings upon completion of system installation, including all,
reference drawings, and hard-copies, per the term-out schedule supplied, and
as-built drawing checklist (to be supplied by Project Owner).
 
H.
 
Provide copies of all Professional Engineering deliverables, including stamps
and signatures on all drawings, and calculation packages as applicable.
 
I.  
Provide technical solutions or correspondence to support system term-outs, as it
relates to Independent Engineering review, in a prompt manner as to support
intended schedule.

 
D.    Construction Scope
 

A.
This Contract Agreement includes, but is not limited to, providing all labor,
material, tools, equipment and supervision to complete the following scope of
work;
 
   
System Supplier shall furnish and Install all required footings, foundations,
slabs, and mounting pads including all required layout, excavation, form work,
reinforcing, anchor bolts and finishing of concrete necessary. The foundation
spoils are to be spread on site and the AC debris shall be stockpiled into a
location as determined by the Project Owner to be hauled off site by Project
Owner.
 
    1. System Supplier shall install in all required footings Conduit supplied
by Project Owner.     2.
System Supplier shall furnish, fabricate, and install all required steel (Tee'
structures including all required layout, hardware, welding, Temporary bracing
during erection, and all other material or equipment for a complete
installation.
    3.
System Supplier shall furnish, fabricate, and install all required steel purlins
and other support member to support the installation of PV modules including all
required layout, hardware, welding, Temporary bracing during erection, and all
other material or equipment for a complete installation.
    4.
Installation of Project Owner provided equipment, as indicated on the provided
"List of Owner Supplied Material and Equipment", including but not limited to
installation of PV Modules.
    5.
Furnish and Install all required miscellaneous mounting hardware, blocking or
other material necessaiy for a complete installation of the work, except where
indicated on "List of Owner Supplied Material and Equipment"
     6.  System Supplier shall perform required Painting and galvanizing
required, including touchup as required      7.  System Supplier is to perform
all required Saw Cutting and or Core Drilling.

 
 
4

--------------------------------------------------------------------------------

 

 

    8.
System Supplier shall remove light poles noted and deliver to the Campus
Facilities Department. The concrete light standards shall be removed to 2" below
finish grade. The concrete debris shall be stockpiled into a location as
determined by the Project Owner to be hauled off site by Project Owner.
 
    9.
System Supplier intends to prefabricate the modules for installation on the
steel structure. System Supplier shall provide any required work benches and
equipment necessaiy to complete the work. System supplier shall allow an
electrician access to the work area to pre-wire the panels prior to erection.
System Supplier and Project Owner shall coordinate the module delivery and
security of the staging area at a later date.
 
B.
In addition the System Supplier shall be responsible for the following:
 
    1.
Ail required labor and equipment for offloading and material placement.
 
    2.
All rigging of materials.
 
    3.
Unloading, inventory, and storage of all material delivered to project site.
 
    4.
Any and all personnel lifts and or scaffold.
 
    5.
All Layout for the System Supplier's work from benchmarks provided by Project
Owner.
 
    6.
System Supplier is responsible for supplying any temporary power and additional
task lighting required to perform its work.
 
    7.
Project Owner shall furnish all required Trash Removal and Dumpsters as required
for work, including off haul of asphalt paving
 
    8.
Maintain all areas free of waste materials, debris, and rubbish. Maintain site
in a clean and orderly fashion.
 
    9.
Supply all required Rental Equipment and any required Small Tools for the
performance of its work.
 
    10.
All required surface preparation.
 
    11.
Repair of any damaged work existing or new; including but not limited to roof
membrane or material, asphalt paving, concrete paving, curb & gutter, or
existing buildings.
 
    12. 
System Supplier shall furnish all required warranties to the Project Owner as
indicated in the attached Warranty Requirements document, including, but not
limited to, all 'workmanship' warranties and assignment to the Owner of all
Manufacturer's warranties.
 
    13. 
Project Owner shall furnish and maintain the required Temporary Restroom
Facilities at the code required numbers and frequency of maintenance.
 

 
5

--------------------------------------------------------------------------------

 

 
E.    Other Conditions
 
A.
System Supplier shall not be entitled to any payment for Field Extra Work Orders
without the signature of Project Owner's Project Superintendent or Construction
Project Manager. The effect of such signature is limited by the terms and
conditions of the Contract Agreement.      
B.
When grounds exist justifying a back charge against the System Supplier, whether
or not due to a default under this Agreement, Project Owner may provide System
Supplier written notice to take appropriate corrective action, as determined by
Project Owner, within twenty-four (24) hours. If System Supplier fails to
commence and satisfactorily continue corrective action to the satisfaction of
Project Owner, then System Supplier shall be liable for all costs and expenses
resulting there from, including, but not limited to, investigation costs, costs
to remedy, mark-up for overhead and profit of fifteen (15%), plus any attorneys'
fees incurred by Project Owner.

 
F.    Exclusions
 

A.
The Work excludes performance or completion bonds for the city, other government
entities or third parties.
 
B.
The Work excludes all materials testing, field testing, field inspections, and
special inspection costs. Such excluded items are to be provided separately by
the Project Owner and paid by the Project Owner at no cost to the System
Supplier.
 
C.
The Work excludes providing payment and performance bonds to the Project Owner.
 
D.
Excludes costs to address architectural treatments for normal shrinkage cracks
in concrete construction.
 
E.
The Work excludes all concrete for Electrical scope of work.
 
F.
The Work excludes PV module washing provisions and equipment.
 
G.
The Work excludes well points or dewatering.
 
H.
The Work excludes installation of any Project Owner furnished items except as
indicated on the "List ofOwner furnished Material and Equipment."
 
I.
The Work excludes all landscaping and re-establishment of existing landscaping.
 
J. Owner shall perform any pavement patching required around the foundation
bases and light fixture bases removed as a result of the work. Supplier shall
provide a concrete base approximately 2" below finish grade to allow a finish
paving application by others.

 
6

--------------------------------------------------------------------------------

 
EXHIBIT C - PROJECT SCHEDULE

 

Project Milestones:         Start Construction (drilling foundations)   
8/3/2009         School Blackout Period ( no work, all parking   lots clean and
available to the campus)   9/7/09 - 9/25/09         Module installation complete
(no later than)   10/21/2009     Final Completion 10/27/2009

 
 
 
 

--------------------------------------------------------------------------------

 
 
 
 
 
[f8k0210ex10xiii_envision22.jpg]           
 
 
 
 
 
Exhibit 'D' -      Payment Form
with Schedule of Values           
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 

--------------------------------------------------------------------------------

 

 
[f8k0210ex10xiii_envision23.jpg]
 
 
 
 
 
1

--------------------------------------------------------------------------------

 

CONTINUATION
SHEET                                                                    AIA
document g 703
AIA Document g702, APPLICATION AND CERTIFICATE FOR PAYMENT, containing
Contractor's signed Certification is attached.
In tabulation below, amounts are stated to the nearest dollar.
Use Column I on Contracts where variable retainage for the line items may apply
  APPLICATION NUMBER:
APPLICATION DATE:
PERIOD TO:
ARCHITECT'
S PROJECT NO:

 
 
A
B
C
D
E
F
G
H
I
ITEM
DESCRIPTION OF WORK
SCHEDULED
WORK COMPLETED
MATERIALS
TOTAL
%
BALANCE
RETAINAGE
NO.
 
VALUE
FROM PREVIOUS
THIS PERIOD
PRESENTLY
COMPLETED
(G+C)
TO FINISH
       
APPLICATION
 
STORED
AND STORED
 
(C-G)
       
(D+E)
 
(NOT IN
TO DATE
               
D OR E)
(D+E+F)
       
Design / Engineering
               
1-330S
Preliminary Design and Engineering
0.00
-
-
-
-
0%
0,00
0.00
1-33DS
Final permit design drawings
0.00
       
0%
0.00
0,00
 
Structure installation
               
2-050S
Demo existing light poles
0.00
-
-
-
-
0%
0.00
0.00
3-300S
Pier foundations
0.00
-
 
-
-
0%
0,00
0.00
5-2QQS
Structural Steel Material
0.00
             
5-200S
Structural Steel - installation
0.00
-
-
-
-
0%
0.00
0,00
16-300S
Module Installation
0.00
 
-
-
-
0%
0.00
0.00
5-20 OS
Paint structural steel
0.00
       
0%
0.00
0.00
   
0
0
0
0
0
 
0.00
0

 
2

--------------------------------------------------------------------------------

 
CONTINUATION
SHEET                                                                    AIA
document g 703
AIA Document g702, APPLICATION AND CERTIFICATE FOR PAYMENT, containing
Contractor's signed Certification is attached.
In tabulation below, amounts are stated to the nearest dollar.
Use Column I on Contracts where variable retainage for the line items may apply
  APPLICATION NUMBER:
APPLICATION DATE:
PERIOD TO:
ARCHITECT'
S PROJECT NO:

 
 
A
B C D E F G H I
ITEM NO.
DESCRIPTION
OF WORK
SCHEDULED VALUE
WORK COMPLETED
MATERIALS
PRESENTLY
TOTAL
COMPLETED
%
(G+C)
BALANCE
TO FINISH
RETAINAGE
     
FROM PREVIOUS
APPLICATION
(D + E)
THIS PERIOD
STORED
(NOT IN
D OR E)
AND STORED
TO DATE
(D+E+F)
 
(C-G)
 
 
CHANGE ORDER #
 -  -  -        -
0.00
     -  -  -        -
0.00
     -  -  -        -
0.00
     -  -  -        -
0.00
     -  -  --        -
0.00
     -  -  -        -
0.00
     -  -  -        -
0.00
     -  -  -        -
0.00
     -  -  -                -  -  -                -  -  -                -  -
 --                -  -  -                -  -  -                -  -  -        
       -  -  -                -  -  -                -  -  -                -  -
 -                -  -  -                -  -  -                -  -  -        
       -  -  -                -  -  -                -  -  -                -  -
 -        -  -

 
 
3

--------------------------------------------------------------------------------

 
 

 
[f8k0210ex10xiii_envision22.jpg]          
 
 
 

 
 
 

  Exhibit 'E' -     Insurance   Requirements

 
 
 
             
         
 
 
 
 
 
 
 
 
 
 
 
 

--------------------------------------------------------------------------------

 
 

1.
Required Coverage.   Subcontractor shall carry and maintain with carriers or
self insurance, as a minimum, the following insurance coverage:
 
  1.1.
Workers Compensation
 
 
 
Workers Compensation Insurance and Employers Liability Insurance in accordance
with the laws of the state of where work may be done with limits for employer's
liability in the minimum amount of $100,000
 
  1.2.
Commercial General Liability coverage with a General Aggregate of $2,000,000 per
occurrence,with the following coverage's;

 

  Per Occurrence $2,000,000   Products & Completed Operations  $1,000,000  
Personal Injury & Advertising Injury  $1,000,000   General Aggregate $2,000,000

 

1.3.
Automotive Liability Insurance covering owned, non-owned and hired automobiles
in the minimum limits of:

 

  Bodily Injury $1,000,000 each person   Bodily Injury $1,000,000 each
occurrence and;   Property Damage $1,000,000 each occurrence      

 
2.
 
Policy Endorsements- All insurance coverage required to be maintained by
Subcontractor under this Agreement shall:
 
  2.1.
 provide a severability of interests or cross liability clause;
 
  2.2.
except in the case of worker's compensation insurance and other statutory
insurances where it would be inappropriate, name each SunEdison Party, the Host,
and others as may be reasonably required by Contractor, as additional insureds;
and
 
  2.3.
to the extent permissible in accordance with the policy, include a waiver of
subrogation by the insurers in favor of each Host, each SunEdison Party, SunEd
Solar, investor, and each of their respective assignees, affiliates, agents,
officers, directors, employees, insurers or policy issuers and a waiver of any
right of the insurers to any set-off or counterclaim, whether by endorsement or
otherwise, in respect of any type of liability of any of the persons insured
under any such policies.
 
3.
Certificates. Subcontractor shall throughout the Agreement period post
certificates and/or memoranda of insurance evidencing the coverage specified in
this Exhibit by providing hardcopy certificates to Contractor.
 
4. Cancellations.       4.1.
All policies of insurance to be secured and maintained by Subcontractor
hereunder shall provide, by endorsement, that the Contractor Representative and
any additional insured where required in writing shall be provided forty-five
(45) days' prior written notice of any material policy changes or cancellations
(except two (2) days for non-payment of premium) and that no such cancellation
or change shall be effective without such notice.
        4.2.
Subcontractor shall immediately notify the Contractor Representative regarding
the occurrence of any of the following events: (a) any significant loss covered
by a policy required to be maintained by this Exhibit; (b) any significant
dispute with an insurer; (c) the early cancellation of any policy; (d) the
failure to pay any premium payment; (e) the failure, for any reason, to maintain
any policy required to be maintained by this Exhibit; and (f) any significant
change in any insurance coverage contracted for by Subcontractor.

 
1

--------------------------------------------------------------------------------

 

 
 

[f8k0210ex10xiii_envision24.jpg]

 

 
 
 
 
2

--------------------------------------------------------------------------------

 
 
 
 
 
 
 
 
IMPORTANT
 
 
 
 
 
If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must bo
endorsed, A statement on this certificate does not confer rights to the
certificate holder in lieu of such endorsement(s).
 
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy,
certain policies may require an endorsement. A statement on this certificate
does not confer rights to the certificate holder in lieu of such endorse
ment(s).
 
 
 
 
DISCLAIMER
 
 
 
 
 
The Certificate of Insurance on the reverse side of this form does not
constitute a contract between the issuing insurers), authorized representative
or producer, and the certificate holder, nor does it affirmatively or negatively
amend, extend or alter the coverage afforded by the policies listed thereon.
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 

 
 
3

--------------------------------------------------------------------------------

 
 
 
 
 
 
[f8k0210ex10xiii_envision25.jpg]
 
 
 
 
 

 
4

--------------------------------------------------------------------------------

 
 
 
 
 
 
 
 
[f8k0210ex10xiii_envision26.jpg]
 
 
 
 
 
 
 

5

--------------------------------------------------------------------------------

 
 
[f8k0210ex10xiii_envision22.jpg]          
 
 
 
 
 
 
 

 

  Exhibit 'F' -         Interim & fina   Lien Wavers    

 
 
          
                          
 
 
 
 
 

 
 
 
 
 
 
 
 
 
 
 
 

--------------------------------------------------------------------------------

 
 
 
 

 
CONDITIONAL WAIVER AND RELEASE
UPON PROGRESS PAYMENT

California Civil Code Section 3262(d)(1)

 
Job/Account
#_______________                                                     
 
Upon receipt by the undersigned of a check
from                                                                                                                        
       
in the sum of $______________payable to____________________________________„
and when the check has been properly endorsed and has been paid by the bank upon
which it is drawn, this document shaii become effective to release any
mechanics' lien, stop notice, or bond right the undersigned has on the job
of __________________________________________        
located
at_________________________________________________________________                                                        
to the following extent:
This release covers a progress payment for labor, services, equipment or
material furnished to
_______________________________________________________________________________________________________________________
through_______________________only and does not cover any retention retained
before or after the release
date or extras furnished before the release date for which payment has not been
received or extras or items furnished after the release date. Rights based upon
work performed or items furnished under a written change order which has been
fully executed by the parties prior to the release date are covered by this
release unless specifically reserved by the claimant in this release. This
release of any mechanics lien, stop notice, or bond right shall not otherwise
affect the contract rights, including rights between parties to the contract
based upon a rescission, abandonment, breach of the contract, or the right of
the undersigned to recover compensation for furnished labor, services, equipment
or material covered by this release if that furnished labor, services, equipment
or material was not compensated by the progress payment. Before any recipient of
this document relies on it, said recipient should verify evidence of payment to
the undersigned.
 
Date:__________________________                                                                                                                              ___________________________
                                          (company name)
                                        By:___________________________
                                          (signature)
                                        ___________________________
                                           (print name)

 
NOTE: CIVIL CODE 3262 (d)(1) PROVIDES: Where the claimant is required to execute
a waiver and release in exchange for, or in order to induce the payment of, a
progress payment and the claimant is not, in fact, paid in exchange for the
waiver and release or a single payee check or joint payee check is given in
exchange for the waiver and release, the waiver and release shall follow
substantially the form set forth above.

 
 
1

--------------------------------------------------------------------------------

 
UNCONDITIONAL WAIVER AND RELEASE
UPON FINAL PAYMENT

California Civil Code Section 3262(d)(4)

Job/Account #_____________________

The undersigned has been paid in full for all labor, services, equipment or
materia! furnished
to:___________________________________________________________________________
on the job of:___________________________________________________________

located
at:__________________________________________________________________________
and does hereby waive and release any right to a mechanics lien, stop notice, or
any right against a labor and material bond on the job, except for disputed
claims for extra work in the amount of
$_________________________________________________________________________________
.

Date:__________________________                                                            ____________________________
                                                                                                                                       
(company
name)                                                                                           
                                                                                                                              
 By:___________________________
          (signature)
___________________________
         (print name)

NOTICE TO PERSONS SIGNING THIS WAIVER: THIS DOCUMENT WAIVES RIGHTS
UNCONDITIONALLY AND STATES THAT YOU HAVE BEEN PAID FOR GIVING UP THOSE RIGHTS.
THIS DOCUMENT IS ENFORCEABLE AGAINST YOU IF YOU SIGN IT, EVEN IF YOU HAVE NOT
BEEN PAID. IF YOU HAVE NOT BEEN PAID, USE A CONDITIONAL RELEASE FORM.

NOTE: CIVIL CODE 3262(d)(4) PROVIDES: Where the claimant is required to execute
a waiver and release in exchange for, or in order to induce payment of, a final
payment and the claimant asserts in the waiver that it has, in fact, been paid
the final payment, the waiver and release shall follow substantially the form
set forth above.

 
 
2

--------------------------------------------------------------------------------

 
 
 
[f8k0210ex10xiii_envision22.jpg]    
 
 
 
 
 

 

 9.   
Exhibit 'H'-      Unit Prices
 

 
 
 
 
 
 

 
 
 
 

--------------------------------------------------------------------------------

 
 
 
[f8k0210ex10xiii_envision22.jpg]   
 
 
 
 
 

 

  
Exhibit 'H'-      Unit Prices
 
  NOT  USED

 
 
 
 
 
 
 
 
 
 
 

 

--------------------------------------------------------------------------------

 
 
 
 
 
 
[f8k0210ex10xiii_envision22.jpg]    
               
 
 
 
 
 
 
  10.   
Exhibit T - Change Order
 
Form

 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 
 

--------------------------------------------------------------------------------

 
 
CHANGE
Attachment F - AiA form G701    
OWNER o
ORDER
 
ARCHITECT
o     CONTRACTOR o AIA DOCUMENT G701   FIELD o     OTHER o        

PROJECT:   CHANGE ORDER NUMBER:     DATE:     PROJECT NO.: TO CONTRACTOR:  
CONTRACT DATE:     CONTRACT FOR:

 
The Contract is changed as follows:

 

No. Description Cost   1.   $  - 2.   $  - 3.   $  - 4.   $  - 5.   $  - 6.   $
 - 7.   $  - 8.   $  - 9.   $  - 10.   $  -    SubTotal     $  -

 

--------------------------------------------------------------------------------

 
This change order constitutes full and final resolution on cost and contract
time for the above issues. The contractor waves all right to any and all future
claims related to the issues addressed herein.

--------------------------------------------------------------------------------

 

The original (Contract Sum) (Guaranteed maximum Price) was   Net change by
previously authorized Change orders   The (Contract Sum) (Guaranteed maximum
Price) prior to this Change order was  
The (Contract Sum) (Guaranteed maximum price) will be (increased) (decreased)
(unchanged) by this Change Order in the amount of
  The new (Contract Sum) (Guaranteed maximum Price) including this Change order
will be  $                                             -               

 
The Contract Time will be (increased) decreased) (unchanged) by
 
The date of Substantial Completion as of the date of this Change Order therefore
is
 
NOTE: 
      This summary does not reflect changes In the Contract Sum, Contract Time
or Guaranteed Maximum Price which have been authorized by Construction Change
Directive.

 
 

          ARCHITECT   CONTRACTOR   OWNER           Address   Address   Address  
        BY   BY   BY           DATE   DATE   DATE

 
 

--------------------------------------------------------------------------------

 
 
[f8k0210ex10xiii_envision22.jpg]    
 
 
 
Exhibit K - List of Owner Furnished Equipment & Material
 
 

 
Project Name:
CSU - Bakersfield - Parking Lot E Canopy
 
Project Number    CA-08-0041 Project Location:    9001 Stockdate HwBakersfield
CA

 
 
 
 

Description   Furnished By Installed By       Yingli YL175 (156) Solar
Modules     SunEdison Contractor

 
 
 
 
 
 
 
 
 
 
7/6/2009

--------------------------------------------------------------------------------

                                                                                            
 
 
[f8k0210ex10xiii_envision22.jpg]    
 
 
WORKMANSHIP WARRANTY
 
This Workmanship Warranty is offered [SELLER/CONTRACTOR], a Delaware limited
liability company ("Contractor") to [PURCHASER] ("Owner") in regard to the
photovoltaic system installed at Owner's premises at [ADDRESS], pursuant to that
certain Agreement Between Owner and Contractor dated as of [DATE] (collectively,
"Agreement").
 

1. 
WORKMANSHIP WARRANTY
 
  1.1. 
Contractor warrants that the System generally defined within the Agreement will
be free from defects in workmanship for the period defined in Section 1.2 of
this Warranty.
 
  1.2. 
The term of this Warranty shall be one (1) year starting from [DATE OF
COMMERICAL OPERATION] (the "Warranty Period").
 
  1.3. 
Except as provided below, if during the Warranty Period the System becomes
inoperable as a result of defects in workmanship to the System, then Contractor
will have the relevant System components repaired or replaced as provided below:
 
    1.3.1. 
The following are System components covered by this Warranty: photovoltaic
modules, inverter, transformer, and racking structure.
 
    1.3.2. 
Consumable items are not included as System components covered by this Warranty.
Consumable items include but are not limited to fuses, batteries, lubricants,
and filters.
 
  1.4.
 
 
  1.5. 
Contractor's obligations under this warranty are dependent on Owner's compliance
with the provisions of Section 3 of this Warranty.
 
2.  
 
 
  2.1. 
The Warranty is only for the benefit of the original purchaser of the System
(i.e., Owner) or its Affiliates.
  
  2.2. 
Contractor may use the services of a subcontractor in supporting this Warranty.
 
  2.3. 
Owner shall at all times provide or arrange reasonable access for Contractor
and/or its subcontractors to the System for purposes of supporting this
Warranty.
 
3. 
 
 
  3.1. 
Owner shall be solely responsible for the operation and maintenance of the
System in strict compliance with the System Operations and Maintenance Manual.
 
  3.2. 
Contractor shall have no obligations under this Warranty or otherwise should
Owner fail to operate and maintain the System in strict compliance with the
System Operations and Maintenance Manual.
 
  3.3.  Contractor's obligations under this Warranty shall be limited solely to
defects which are direct and obvious defects in Contractor's workmanship.

 
 
Page 1 of 3

--------------------------------------------------------------------------------

 
 
[f8k0210ex10xiii_envision22.jpg]    
 
 
 

4. 
CLAIMS UNDER WORKMANSHIP WARRANTY
 
  4.1.
The Owner shall designate an employee to serve as the System Manager. The System
Manager is the operator of the System and is required to perform the activities
defined in the Operations and Maintenance Manual.
 
  4.2. 
The System manager may request inspection of the System by making a claim under
this Warranty. To make a claim, the System Manager must:
 
    4.2.1. 
 Identify a fault condition in the System.
 
    4.2.2. 
Conduct preliminary troubleshooting in accordance with the Operations and
Maintenance Manual.
 
    4.2.3. 
Contact Contractor's Service Manager or his designee.
 
    4.2.4. 
Perform reasonable troubleshooting of the System requested by the Contractor's
Service Manager or his designee.
 
    4.2.5. 
Notify Contractor's Service Manager in writing to the contact information
provided below that service is required in response to a claim under this
Warranty.
 
      [FULL contact information]

 

  4.3 
Contractor or Contractor's subcontractor will respond to a claim under this
Warranty as described below:
 
    4.3.1.
Contractor will ensure trained maintenance personnel respond within 72 hours
following receipt of a service request as specified in 4.2.5.
 
   
4.3.2.  
Contractor will repair or replace any faulty System component as provided in 1.3
above in a timely manner, but in no event later than eight (8) weeks from time
of such request subject to material availability.
 
    4.3.3. 
If upon inspection of the System, it is determined that (i) the System is
operating within applicable specifications or (ii) that the cause of
inoperability of the System is excluded or limited under this Warranty, Owner
will be liable for any reasonable labor and material expenses incurred by
Contractor in connection with the service call.
 
  4.4   
When performing any work under this Warranty, Contractor has the right, at its
sole discretion, to repair or replace all or part of the System using new,
remanufactured or refurbished parts or products provided said "parts" are of
equal or greater quality of the part being replaced; provided that, if any
defect is due to a design flaw in any part, Contractor shall, at its sole
option, repair or replace such part with an acceptable substitute therefore. Any
original part that is removed and substituted with a replacement part will
become the property of Contractor, and the replacement part will become property
of Owner.
 

 
 
Page 2 of 3

--------------------------------------------------------------------------------

 
 
[f8k0210ex10xiii_envision22.jpg]    
 
 
 

 5.  
 WORKMANSHIP WARRANTY EXCLUSIONS AND LIMITATIONS
 
  5.1.
No other warranty to Owner or any other person, whether express, implied or
statutory, is made as to the installation, design, description, quality,
merchantability, completeness, useful life, future economic viability, or
fitness for any particular purpose of the System or any other service provided
hereunder or described herein, or as to any other matter, all of which are
expressly disclaimed by Contractor.
 
  5.2. 
The Warranty provided herein does not cover damage, malfunctions or service
failures caused by:
 
    5.2.1.
Failure to follow the Operations and Maintenance Manual or other maintenance
instructions provided by Contractor in all material respects;
 
    5.2.2. 
Repair, modification, or movement of the System or components thereof by someone
other than a service technician approved by Contractor or attachment to the
System of equipment not supplied by Contractor;
 
    5.2.3. 
Abuse, misuse, or negligent acts of any Person (other than Contractor, its
subcontractors, and their respective employees, representatives and agents); or
 
    5.2.4. 
Damage or deteriorated performance of the System caused by electrical surges (to
the extent not caused by the System or any portion thereof), lightning, fire,
flood, extreme weather creating conditions outside of the Specifications for
such System, pest damage, accidental breakage (not including accidental breakage
by Contractor, its subcontractors, and their respective employees,
representatives and agents)), actions of third parties (other than Contractor,
its subcontractors, and their respective employees, representatives and agents)
and other events or accidents outside the reasonable control of Contractor, its
subcontractors, and their respective employees, representatives and agents and
not arising under normal operating conditions.
 
6. 
ASSIGNMENT OF MANUFACTURERS' WARRANTIES. Contractor hereby assigns to Owner all
manufacturers' warranties as to the System's solar panels and inverter.
 
7. The Contractor shall meet or exceed all local, State or utility specific
requirements including, but not limited to those under the California Solar
initiative Program. These include the following per section 2.4 - All systems
must have a minimum 10-year warranty provided in combination by the manufacturer
and installer to protect the purchaser against defective workmanship, system or
component breakdown, or degradation in electrical output of more than fifteen
percent from their originally rated electrical output during the ten-year
period. The warranty must cover the solar generating system only, including PV
modules (panels) and inverters, solar collectors, tracking mechanisms,
associated with the solar system and provide for no-cost repair or replacement
of the system or system components, including any associated labor during the
warranty period.

 
 
 
 
December 31,2008
 
Page 3 of 3

--------------------------------------------------------------------------------