DENIED: July 29, 2019
CBCA 4241
UCENSYS RESEARCH CORP.,
Appellant,
v.
NUCLEAR REGULATORY COMMISSION,
Respondent.
Christopher Lee, Director, Research and Technology, of Ucensys Research
Corporation, Ashburn, VA, appearing for Appellant.
Michael L. Norris, Office of the General Counsel, Nuclear Regulatory Commission,
Washington, DC, counsel for Respondent.
Before Board Judges KULLBERG, ZISCHKAU, and SULLIVAN.
KULLBERG, Board Judge.
Appellant, Ucensys Research Corporation (Ucensys), appeals the contracting officer’s
(CO’s) termination for cause of an order for renewal of service coverage for video
teleconference (VTC) equipment and the CO’s demand for repayment of the contract price
in the amount $64,784.53. Ucensys contends that its failure to provide the ordered services
was due to circumstances beyond its control. The Board conducted a hearing in this appeal,
and the parties submitted briefs. For the reasons stated below, the Board denies the appeal
and directs appellant to repay $64,784.53.


CBCA 4241 2
Background
On October 17, 2013, the Nuclear Regulatory Commission (NRC) issued solicitation
number ADM-14-010 (solicitation), which was reposted on October 21, 2013, for the
purchase of Cisco SmartNet enterprise content delivery network (ECDN) service for
forty-four items of CISCO/Tandberg VTC equipment. Appeal File, Exhibits 37-39. 1 The
solicitation had two contract line item numbers (CLINs). Exhibit 38 . CLIN 001 was for
“Cisco SmartNet ECDN Service Coverage for one year from 12/1/2013 through
11/30/2014[,]” and CLIN 002 was for “[r]einstatement charge [that may be] applicable to
product(s) that have a [lapse] in coverage.”Id. The solicitation was limited to “sources that
are authorized by Cisco to sell the required services.”Id. at 2.
NRC issued the solicitation after it determined that forty-four items of VTC
equipment, which were identified by serial numbers, required “renewal of CISCO SmartNet
ECDN maintenance and support plans for a period of one year.” Exhibit 1
at 1. Additionally, NRC determined that the existing “Cisco/Tandberg warranty service
agreements . . . [had] expired or will expire in calendar year 2013.Id. at 3. NRC contacted
Cisco in September of 2013 “to get an estimate of what one year service will cost.” Exhibit 4
at 2. Cisco provided an estimate, which was dated September 7, 2013. Exhibit 50. NRC
used that estimate from Cisco to establish an independent government estimate. Transcript,
Vol. 1 at 51-52. That estimate from Cisco also confirmed that renewal of service coverage
could be obtained for all forty-four of the items of VTC equipment, and any potential bidder
would have been able to obtain that same information from Cisco. Id.
After receipt of bids in response to the solicitation, NRC determined that some of the
bids did not include a price for reinstatement fees under CLIN 002. Exhibit 4, at 2. NRC
then issued “[a] repost . . . requesting bidders to ensure they include full reinstatement fee
(if applicable) to their current bid.”Id. at 1. Ucensys submitted its final bid on December 3,
2013, in the form of an invoice for $64,784.53. Exhibit 15 at 4.
On December 18, 2013, NRC awarded purchase order NRC-HQ-40-14-P-0001 (order)
to Ucensys to “[p]rovide funding for CISCO SmartNet ECDN service for 44
CISCO/Tandberg equipment items at the NRC.” Exhibit 14 at 3. The order required
Ucensys to purchase service coverage for the period from December 1, 2013, to
November 30, 2014, and the obligated amount of award under the contract was
$64,784.53. Id. at 2. The contract schedule stated, “Delivery of supplies or services to the
NRC by 1/1/2014.”Id. Ucensys’ contract price consisted of CLIN 001 in the amount of
1 All exhibits are found in the appeal file, unless otherwise noted.

CBCA 4241 3
$47,689, and CLIN 002 in the amount of $17,095.53. Id. On December 24, 2013, NRC
approved Ucensys’ invoice for the full amount of the order, $64,784.53. Exhibit 15.
The order incorporated in full Federal Acquisition Regulation (FAR) clause, 48 CFR
52.212-4 (2013) (FAR 52.212-4), contract terms and conditions–commercial items (JUL
2013). Exhibit 14 at 2-9. That clause provided in pertinent part, the following:
(d) Disputes. This contract is subject to the Contract Disputes Act of 1978,
as amended (41 U.S.C. [§§ 7101-7109 (2012)]). Failure of the parties to this
contract to reach agreement on any request for equitable adjustment, claim,
appeal or action rising under or relating to this contract shall be a dispute to be
resolved in accordance with the clause at FAR 52.233-1, Disputes, which is
incorporated herein by reference. The Contractor shall proceed diligently with
performance of this contract, pending final resolution of any dispute arising
under the contract.
. . . .
(f) Excusable delays. The Contractor shall be liable for default unless
nonperformance is caused by an occurrence beyond the reasonable control of
the Contractor and without its fault or negligence such as, acts of God or the
public enemy, acts of the Government in either its sovereign or contractual
capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually
severe weather, and delays of common carriers. The Contractor shall notify
the Contracting Officer in writing as soon as it is reasonably possible after the
commencement of any excusable delay, setting forth the full particulars in
connection therewith, shall remedy such occurrence with all reasonable
dispatch, and shall promptly give written notice to the Contracting Officer of
the cessation of such occurrence.
. . . .
(m) Termination for cause. The Government may terminate this contract,
or any part hereof, for cause in the event of any default by the Contractor, or
if the Contractor fails to comply with any contract terms and conditions, or
fails to provide the Government, upon request, with adequate assurances of
future performance. In the event of termination for cause, the Government
shall not be liable to the Contractor for any amount for supplies or services not
accepted, and the Contractor shall be liable to the Government for any and all
rights and remedies provided by law. If it is determined that the Government

CBCA 4241 4
improperly terminated this contract for default, such termination shall be
deemed a termination for convenience.
Id. at 2-3, 6.
Although Ucensys was an authorized reseller of Cisco service coverage it could not
obtain a renewal of service coverage under the order for NRC’s VTC equipment directly
from Cisco, but, instead, Ucensys’ agreement with Cisco required that it purchase such
services from a Cisco-authorized distributor. Exhibit 29 at 2-3; Transcript, Vol. 2 at 225-29.
Ucensys sought to obtain service coverage renewal from Tech Data Corporation (Tech Data),
which was a Cisco-authorized distributor, and on December 13, 2013, Tech Data provided
Ucensys with “takeover quotes.” Exhibit 40 at 6-7; Transcript, Vol. 2 at 276. Ucensys’ reply
to Tech Data in response to the quote was the following:
Regarding this quote the period of performance is one year from the time the
warranty starts through 09/30/2014. Because Cisco maintains continuous
service on their equipment, there may be a reinstatement fee on items that have
lapsed in coverage. The current end date you have is December 12, 2014.
Please advise.
Exhibit 40 at 6. In an email dated December 16, 2013, Tech Data informed Ucensys that it
had “a different difference amount.”Id. at 4. In a later email, which was dated January 3,
2014, Tech Data informed Ucensys that it “won’t be able to cover the difference on price
during the time [they] have been working on this quote.”Id. at 1.
During January of 2014, NRC learned that service coverage for one of the items of
VTC equipment had not been updated. Transcript, Vol. 1 at 42. On January 27, 2014, NRC
advised Ucensys that one of the items of VTC equipment had an expired service agreement.
Exhibit 43 at 2. That same day, Ucensys advised the NRC of the following:
Regarding the support issue there seems to have been confusion from the
distributor (not Cisco) end which prevented us from issuing a [purchase order
(PO)]. My team . . . [is] working to get this resolved. I will keep you posted
and please continue to reach out to me with any questions/concerns.
Id.
On May 5, 2014, Cisco advised NRC that the service coverage for all but two of the
serial numbers for the VTC equipment listed in the order had expired. Exhibit 46; Transcript,
Vol. 1 at 62. NRC forwarded that information to Ucensys by email that same day.

CBCA 4241 5
Exhibit 46. In an email message dated May 27, 2014, NRC informed Ucensys of the
following:
The NRC’s fleet of VTC units must be registered for maintenance coverage
with Cisco by [close of business] tomorrow. . . . Your invoice . . . in the
amount of $64,784.53 has already been paid in full. Six months later, we are
finding out that our units are still not registered. This is unacceptable. Please
provide a path forward no later than 10 a.m. tomorrow.
Exhibit 16 at 4. Ucensys replied to NRC in an email message, which was dated May 28,
2014, that stated the following:
I would suggest modifying the original PO to exclude the piece of inventory
(Serial 62.11914 CTS-6000-50-MK2-P). This piece of inventory is not
eligible for Smartnet coverage as of December 31, 2013 it reached
‘End-of-Life[.’] According to Cisco the NRC was provided with notice, and
further, this serial should not have been included in the original PO issued last
year. Once we receive and sign off on the amended PO we can proceed with
covering all eligible VTC equipment.
Id. at 3. The phrase “end of life” meant that service coverage was no longer available, but
continued coverage could be arranged even under those circumstances. Transcript, Vol. 1
at 66-68. Warranty coverage on the other items of VTC equipment under the contract would
not have been affected because one item was at “end of life.”Id. at 76-77.
The CO responded to Ucensys in an email, which was dated May 28, 2014, that stated
the following:
Pursuant to the contract you signed with the NRC on December 19, 2013,
Ucensys Research Corporation agreed to perform maintenance and support on
44 CISCO/Tandberg equipment items owned by the NRC. You accepted the
contract as-written and that obligation does not change unless both signing
parties agree to modify the contract. According to my understanding of the
situation . . . there exists an issue over whether certain pieces of equipment
listed under the contract can still be serviced or whether they have reached
their “end-of-life” and thus are no longer eligible to be serviced by Cisco, and
that this in turn seems to be related somehow to your failure to perform any
other parts of the contract.

CBCA 4241 6
Exhibit 16 at 1. Additionally, NRC instructed Ucensys to confirm by June 2, 2014, its intent
to perform the services required under the order for the remaining VTC equipment. Id.
In its June 2, 2014, email message in response to the CO, Ucensys stated the
following:
It is our intention to fulfill the requirements of this contract. It is our position
that the performance delays are excusable and have been caused by
circumstances beyond the control of Ucensys.
. . . .
Cisco was unable to restructure the dates of coverage to reflect an End Date
of 9/30/2014 for all Inventory Equipment. The NRC should have been notified
by Cisco during the [request for proposals (RFP)] process that because this
was a ‘Takeover’ quote[,] Cisco cannot change the dates. If this information
would have been known when preparing the RFP[,] then Ucensys staff would
not have had to spend time researching the issue that was not in the scope of
services. Consequently[,] this caused a performance delay.
. . . .
The second occurrence is One(1) out of 44 Cisco/Tandberg equipment items
was not eligible for Cisco SMARTnet ECDN Service Coverage.
CTS-6000-50-MK2-P. The last date of support . . . was December 31, 2013.
Exhibit 17 at 1. Ucensys concluded by recommending that “we proceed with the SMARTnet
service coverage on the eligible equipment.”Id. at 2.
Representatives from NRC and Ucensys conferred by phone on June 4, 2014, and
Ucensys agreed to provide service coverage on forty-three of the forty-four items of VTC
equipment by June 6, 2014. Exhibit 20 at 2; Transcript, Vol. 1 at 82-83. NRC’s email
message to Ucensys, which was dated June 4, 2014, stated the following:
Per our conversation this morning, please confirm that 43 of the 44 pieces of
equipment (referenced in your email below) will be registered for maintenance
coverage with Cisco [not later than] 3 p.m. Friday, June 6, 2014 or sooner.

CBCA 4241 7
Once this is completed, the Contracting Officer will get in touch with you to
discuss the one item of equipment that is unresolved.
Exhibit 19.
Ucensys did not respond to NRC’s June 4, 2014, email and failed to provide renewal
of service coverage for the remaining forty-three items of VTC equipment by June 6,
2014. Exhibit 20; Transcript; Vol. 1 at 85. On June 13, 2014, NRC sent a cure notice to
Ucensys that stated, in pertinent part, the following:
The last time our office spoke with you, in a telephone conference on June 4,
2014, you indicated that you would have the coverage in place for 43 of the 44
pieces of equipment by June 6, 2014. Today, one full week after that June 6
deadline, there is still no Cisco SmartNet ECDN coverage on any of NRC’s
equipment. Cisco indicated as late as June 11, 2014[,] that Ucensys has still
not placed the order with Cisco for the required coverage. While we
understand that securing coverage on one of the 44 pieces of equipment is no
longer possible, there is no apparent reason why Ucensys has not yet secured
coverage on any of the other 43 pieces of equipment six months after
Ucensys[’] acceptance of the purchase order, when that coverage should have
been in place immediately after purchase order acceptance in December 2013.
Exhibit 22. Ucensys did not respond to the NRC’s cure notice. Transcript, Vol. 1 at 177-78.
NRC confirmed through Cisco that Ucensys had not obtained a service agreement for any of
the VTC equipment under the contract.Id. at 178. Ucensys did not communicate with NRC
subsequent to the cure notice, and NRC had no reason to believe that Ucensys had made any
effort to cure the situation. Id. at 179.
On June 24, 2014, Tech Data sent Ucensys an email that stated the following:
The requirements were not clear. There were two different requests, with little
information. Every time I’ve opened a case with Cisco, I’ve uncovered a new
issue. I have been trying my best to get this completed, but as you know there
is a process with Cisco. This was completed before, but you requested for me
to start over. I understand your frustration, but please understand that I’m
aligning my resources to get you an updated quote. I will keep you
posted. Thanks!
Exhibit 35. NRC did not receive a copy of that email. Transcript, Vol. 1 at 204. The CO
terminated the order for cause in a letter to Ucensys dated July 1, 2014. Exhibit 23. In a

CBCA 4241 8
second letter to Ucensys dated August 21, 2014, the CO demanded repayment of NRC’s
previous payment $64,784.53 as a result the termination of the order for cause. Exhibit 26.
The Board held an oral hearing in this appeal, and the parties submitted briefs.
Discussion
The issue before the Board is whether NRC properly terminated the order for cause
and can recover its previous payment to Ucensys in the amount of $64,784.53. NRC
contends that Ucensys failed to obtain renewals of service coverage for any of the items of
VTC equipment listed in the order, and Ucensys has failed to show that its failure to perform
the terms of the order was excusable. Additionally, NRC argues that it is entitled to recover
the full amount of its invoice payment of $64,784.53 to Ucensys. Ucensys contends that its
failure to perform the contract was due to circumstances beyond its control.
This Board recognizes that “a default termination is a ‘drastic sanction’ that the
Government should impose ‘only for good grounds.’”Brent Packer v. Social Security
Administration, CBCA 5038, et al., 16-1 BCA ¶ 36,260, at 176,898-99 (quotingJ.D. Hedin
Construction Co. v. United States , 408 F.2d 424, 431 (Ct. Cl. 1969)). In the case of a
commercial items contract, “a termination based upon a failure to comply with ‘any contract
terms and conditions’ under the commercial item clause requires that those contract terms
and conditions constitute material requirements of the contract.Id. at 176,899 (citingPriebe
& Sons, Inc. v. United States , 332 U.S. 407, 413 (1947)). “Under FAR 52.212-4(m), the
termination for cause clause for commercial services contracts, the government initially has
the burden of proving that the termination for cause was valid.”Id. (quoting KSC-TRI
Systems, USA, Inc. , ASBCA 54638, 06-1 BCA ¶ 33,145, at 164,260 (2005)). “If the
Government presents a prima facie case that the termination was proper, the burden shifts
to the contractor to rebut the prima facie case.”ACM Construction & Marine Group, Inc.
v. Department of Transportation, CBCA 2245, et al., 14-1 BCA ¶ 35,537, at 174,150 (citing
CDA, Inc. v. Social Security Administration, CBCA 1558, 12-1 BCA ¶ 34,990, at 171,971;
Integrated Systems Group, Inc. v. Social Security Administration, GSBCA 14054-SSA, 98-2
BCA ¶ 29,848, at 147,742). Once the Government has shown that a contractor did not
complete its contract in a timely manner, the contractor has the burden of proving that its
failure to perform its contract was excusable.See DCX, Inc. v. Perry, 79 F.3d 132, 134 (Fed.
Cir. 1996) (citing Lisbon Contractors, Inc. v. United States , 828 F.2d 759, 764 (Fed. Cir.
1987; Switlik Parachute Co. v. United States, 573 F.2d 1228, 1234 (Ct. Cl. 1978)).
Ucensys failed to renew service coverage for any of the items of VTC equipment as
required under NRC’s order. Although Ucensys invoiced and received payment for
providing that service coverage, it failed to do so before January 1, 2014, as required under
the order, or at any time after that date. Ucensys attempted to purchase the service coverage

CBCA 4241 9
from Tech Data, which was a Cisco distributor, but never finalized such a purchase. In spite
of its failure to obtain the service coverage required under the order, Ucensys repeatedly
assured NRC that it would comply with the terms of the order. NRC finally issued a cure
notice on June 4, 2014, but Ucensys did not submit any response. It appears from the record
that one item of VTC equipment became ineligible for service coverage from Cisco because
it had reached its “end of life.” Ucensys requested that NRC modify the order to reflect
that change, but NRC directed Ucensys to obtain service coverage for the remaining
forty-three items of VTC equipment. NRC properly directed Ucensys to proceed as directed
and was not required to issue such a modification because the order incorporated the
Disputes clause, FAR 52.233-1, and Ucensys was obligated to continue performance of the
order. See Alliant Techsystems, Inc. v. United States, 178 F.3d 1260, 1277 (Fed Cir 1999).
The Board finds that NRC has established a prima facie case for terminating the order
for cause, and the Board’s discussion, accordingly, turns to whether Ucensys has met its
burden of proving its nonperformance was excusable. Before issuing the solicitation, NRC
obtained an estimate from Cisco for the cost of obtaining service coverage, and such
information would have been available to any prospective bidder. Ucensys, therefore, had
the ability to determine in advance of award whether it could obtain service coverage before
accepting award of the order. Ucensys obtained “takeover quotes” from Tech Data on
December 13, 2013. As a reseller, Ucensys had to obtain service coverage from a distributor
such as Tech Data because it could not purchase such coverage directly from Cisco, but
Ucensys never completed its purchase from Tech Data. A series of email exchanges between
Ucensys and Tech Data show that they never reached an agreement as to terms for the service
coverage required under the order. Tech Data’s June 24, 2014, email acknowledges
Ucensys’ “frustration,” but also, Tech Data noted that the requests had “little information”
and that Ucensys had requested that Tech Data “start over.”
Ucensys argues that its failure to obtain the required service coverage under the order
was due to circumstances beyond its control, but the Board does not find that Ucensys has
proven that fault lies with any other party. Before agreeing to perform a contract, a
contractor “must examine the complexity of the contract requirements and its own
capabilities, and then make a business judgment as to whether it could complete the work
within the time allowed by the contract.”Ryll International, LLC v. Department of
Transportation, CBCA 1143, 11-2 BCA ¶ 34,809, at 171,305 (citingAmerican Ship Building
Co. v. United States , 654 F.2d 75, 78-79 (Ct. Cl. 1981)). The Board does not find that
Ucensys has offered any persuasive evidence to show that its failure to perform the order was
due to either Cisco or Tech Data, which was suggested in its representative’s testimony.
Transcript, Vol. 2 at 374-75. As discussed above, the documentary record shows that
Ucensys gave repeated assurances to NRC that it would perform the terms of the order, and
those assurances belie its effort to now show that it could not perform the order because of

CBCA 4241 10
the actions of another party. Ucensys’ failure to obtain service coverage for NRC’s VTC
equipment, consequently, is not excused under such circumstances. See Zios Corp .,
ASBCA 56626, 10-1 BCA ¶ 34,344, at 166,620 (termination for cause upheld where
contractor failed to obtain “CISCO SMARTnet agreement” through an authorized source).
The Board addresses, finally, NRC’s demand for repayment of $64,784.53. Pursuant
to FAR 52.212-4(m), the Government can recover from a contractor the amounts paid for
work not performed when a contract is terminated for cause. See Commissioning Solutions
Global, LLC, ASBCA 57429, et al., 13 BCA ¶ 35,355, at 173,531. NRC paid, in full,
Ucensys’ invoice only to receive none of the service coverage for the VTC equipment listed
in the order. Having properly terminated the order for cause, NRC has the right to demand
that Ucensys repay in full the amount of $64,784.53.
Decision
The appeal is DENIED. Appellant shall pay the Government $64,784.53.
H. Chuck Kullberg
H. CHUCK KULLBERG
Board Judge
We concur:
Jonathan D. Zischkau Marian E. Sullivan
JONATHAN D. ZISCHKAU MARIAN E. SULLIVAN
Board Judge Board Judge