Kmisener/CBCA_Full huggingface dataset:
DISMISSED WITH PREJUDICE:  December 9, 2024
CBCA 7152
FRAMACO INTERNATIONAL INC.,
Appellant,
v.
DEPARTMENT OF STATE,
Respondent.
Douglas L. Patin, Erik M. Coon, and Jennifer M. Ersin of Bradley Arant Boult
Cummings LLP, Washington, DC; and Sam Z. Gdanski and Abraham S. Gdanski of Gdanski
Law PC, Teaneck, NJ, counsel for Appellant.
Matthew S. Tilghman and Alexandra N. Wilson, Office of the Legal Adviser,
Buildings and Acquisitions, Department of State, Washington, DC, counsel for Respondent.
RUSSELL, Board Judge.
ORDER
On December 6, 2024, the parties filed a joint motion to dismiss this appeal with
prejudice pursuant to Board Rule 12(b)(2) (48 CFR 6101.12(b)(2) (2023)) and their
September 16, 2024, settlement agreement.  The motion is granted, and the appeal is
DISMISSED WITH PREJUDICE.
   Beverly M. Russell           
BEVERLY M. RUSSELL
Board Judge
__________________________________ 
  
 
DISMISSED WITH PREJUDICE: February 8, 2011 
CBCA 2048 
NEW YORK INTERNATIONAL ENTERPRISES, 
Appellant, 
v. 
DEPARTMENT OF THE TREASURY, 
Respondent. 
Amram Weinstock and Fivel Sofer, Owners of New York International Enterprises, 
Brooklyn, NY, appearing for Appellant. 
Melissa M. Nasrah and Jeffrey E. Warner, Executive Office of Asset Forfeiture, 
Department of the Treasury, Washington, DC, counsel for Respondent. 
McCANN , Board Judge. 
ORDER 
On June 16, 2010, New York International Enterprises filed a notice of appeal in 
connection with a dispute for an item purchased at auction. On February 4, 2011, the parties 
filed a joint motion to dismiss with prejudice in accordance with their settlement agreement. 
Accordingly, this appeal is DISMISSED WITH PREJUDICE . 
R. ANTHONY McCANN 
Board Judge
GRANTED IN PART:  November 20, 2008 
CBCA 1401 
LEON D. DeMATTEIS CONSTRUCTION CORP., 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
David Westermann, Jr. of Westermann Hamilton Sheehy Aydelott & Keenan, LLP, 
Garden City, NY; and Michael J. Schaengold and Robert S. Brams of Patton Boggs, LLP, 
Washington, DC, counsel for Appellant. 
Thomas Y. Hawkins, Office of General Counsel, General Services Administration, 
Washington, DC, counsel for Respondent. 
Before Board Judges SOMERS , VERGILIO , and STEEL . 
STEEL , Board Judge. 
On November 10, 2008, appellant, the Leon D. DeMatteis Construction Corp., filed 
an appeal with the Board from a November 7, 2008, decision by a General Services 
Administration (GSA) contracting officer under contract no. GS-02P-04-DTC-0032(N).  On 
November 18, 2008, this Board received a stipulation for partial judgment which notes that 
the parties have reached a settlement on claims raised in the appeal as a result of mediation. 
The parties have agreed to the immediate entry of partial judgment in favor of appellant in 

 
   
   
 
 
    
    
  
 
                                                                                             
                                          2 CBCA 1401
the amount of $17 million to be paid by GSA, with interest allowable under the Contract 
Disputes Act (CDA), 41 U.S.C. §§ 601- 613(2000), commencing thirty days from the date 
of this order.  They have further agreed that they shall not seek review or reconsideration of 
this partial judgment, and waive their rights to reconsideration under Board Rule 26, rights 
to relief from judgment under Rule 27, and rights to appeal the decision. 
The parties have also agreed to a second partial judgment to be entered upon the 
completion of the project at issue, in an amount to be determined pursuant to a written 
settlement agreement. They request that the Board suspend the balance of this proceeding 
until the amount of the second partial judgment can be determined under that agreement. 
Decision 
Accordingly, the Board GRANTS IN PART this appeal in favor of appellant in the 
amount of $17 million plus interest under the CDA commencing thirty days from the date of 
this order.  The Board suspends the balance of the appeal until further order of the Board. 
The parties are to submit a joint status report no later than December 31, 2009. 
We concur: 
_____________________ 
CANDIDA S. STEEL 
Board Judge 
JERI K. SOMERS 
Board Judge 
JOSEPH A. VERGILIO 
Board Judge
___________________________ 
  
 
DISMISSED WITH PREJUDICE: January 5, 2012 
CBCA 2462 
RAINIER GSA BIRMINGHAM LEASECO, LLC, 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
Salmeh K. Fodor of Marchman, Kasraie & Fodor, LLC, Atlanta, GA, counsel for 
Appellant. 
Amy A. Cook and John Ringhausen, Office of Regional Counsel, General Services 
Administration, Atlanta, GA, counsel for Respondent. 
SOMERS , Board Judge. 
ORDER 
On June 13, 2011, Rainier GSA Birmingham LeaseCo, LLC (Rainier) appealed the 
final decision of a General Services Administration contracting officer denying Rainier’s 
claim under lease contract number GS-04B-45056. 
On January 4, 2012, the parties filed a joint motion to dismiss this appeal with 
prejudice. 
Accordingly, this appeal is DISMISSED WITH PREJUDICE . 
JERI KAYLENE SOMERS 
Board Judge
DISMISSED WITH PREJUDICE:  October 12, 2023
CBCA 6851
GC WORKS, INC.,
Appellant,
v.
DEPARTMENT OF TRANSPORTATION,
Respondent.
Nicholas T. Solosky and Diana Lyn Curtis McGraw of Fox Rothschild LLP,
Washington, DC, counsel for Appellant.
Milton Hsieh, Office of the Chief Counsel, Federal Highway Administration,
Department of Transportation, Sterling, VA; and Kristina Porzio, Office of the Chief
Counsel, Federal Highway Administration, Department of Transportation, Lakewood, CO,
counsel for Respondent.
KULLBERG, Board Judge.
ORDER
On October 10, 2023, the parties jointly requested that this appeal be dismissed with
prejudice.  Accordingly, this appeal is DISMISSED WITH PREJUDICE.
    H. Chuck Kullberg         
H. CHUCK KULLBERG
Board Judge
DISMISSED WITH PREJUDICE: June 7, 2007
CBCA 480 
URBAN SERVICES GROUP, INC./
MERIDIAN MANAGEMENT CORP. JOINT VENTURE,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Michael A. Gordon of Holmes & Gordon, Rockville, MD, counsel for Appellant.
Leonard E. Lucas III, Office of General Counsel, General Services Administration,
Washington, DC, counsel for Respondent.
PARKER , Board Judge.
ORDER
On September 15, 2006, Urban Services Group, Inc./Meridian Management Corp.
Joint Venture appealed the final decision of a General Services Administration contracting
officer regarding proposed payment deductions under contract number GS05P03GAC0065
for mechanical operations and maintenance services at the John C. Kluczynski Federal
Building in Chicago, Illinois.  On June 6, 2007, the parties filed a joint motion to dismiss this
appeal with prejudice.

CBCA 480 2
Accordingly, this appeal is DISMISSED WITH PREJUDICE .
___________________________
ROBERT W. PARKER
Board Judge
DISMISSED WITH PREJUDICE: December 9, 2013
CBCA 3400
GREAT LAKES DOCK & MATERIALS, L.L.C.,
Appellant,
v.
DEPARTMENT OF HOMELAND SECURITY,
Respondent.
Thomas M. Keranen, Bret S. Wacker, and Jeffrey M. Gallant of Clark Hill PLC,
Detroit, MI, counsel for Appellant.
William H. Butterfield, Office of Procurement Law, Headquarters, U.S. Coast Guard,
Department of Homeland Security, Washington, DC, counsel for Respondent.
DANIELS, Board Judge (Chairman).
ORDER
The United States Coast Guard contracted with Great Lakes Dock & Materials,
L.L.C., for construction of the Munuscong Channel Junction Light at the Coast Guard station
in St. Ignace, Michigan.  During performance of the contract, an uplift failure occurred while
the contractor was placing concrete into the steel ice protection cone.  The contractor
maintained that this problem was caused by a Coast Guard design error and claimed that as
a consequence, the contract price should be increased by $282,955.61 and the contract
duration enlarged by twelve calendar days.  The contracting officer denied the claim, and the
contractor appealed his decision.


CBCA 3400 2
The parties have now reached a full and final settlement of all issues in the appeal and
have jointly asked the Board to dismiss the appeal with prejudice.
Accordingly, the appeal is DISMISSED WITH PREJUDICE.
_________________________
STEPHEN M. DANIELS
Board Judge
DISMISSED WITH PREJUDICE:  May 18, 2026
CBCA 8598
CPI-RAINIER LV I DST,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Diana Parks and Hadeel N. Masseoud of Curran Legal Services Group, Inc., Marietta,
GA, counsel for Appellant.
David G. Fagan, Office of General Counsel, Department of Veterans Affairs, Bend,
OR, counsel for Respondent.
SULLIVAN, Board Judge.
ORDER
By motion filed May 14, 2026, appellant requested that the appeal be dismissed with
prejudice, pursuant to Rule 12(b)(2) (48 CFR 6101.12(b)(2) (2025)).  The appeal is
DISMISSED WITH PREJUDICE.
    Marian E. Sullivan         
MARIAN E. SULLIVAN
Board Judge
DISMISSED WITH PREJUDICE: March 4, 2014
CBCA 3431
J. E. HURLEY CONSTRUCTION, INC.,
Appellant,
v.
DEPARTMENT OF AGRICULTURE,
Respondent.
Scott J. Mikulecky of Sherman & Howard, L.L.C., Colorado Springs, CO; and John
A. Bachmann of John A. Bachmann, P.C., Littleton, CO, counsel for Appellant.
L. Benjamin Young, Office of the General Counsel, Department of Agriculture,
Washington, DC; and Daniel B. Rosenbluth, Office of General Counsel, Department of
Agriculture, Denver, CO, counsel for Respondent.
DANIELS, Board Judge (Chairman).
ORDER
The Department of Agriculture’s Forest Service contracted with J. E. Hurley
Construction, Inc. for road and bridge construction in the San Juan National Forest in
Colorado.  The contractor claimed entitlement to an equitable adjustment of $220,178 to the
contract price, to compensate for additional excavation, embankment, and caisson work, and
for costs associated with delays to the project.  The contracting officer denied the claim, and
the contractor appealed the decision.


CBCA 3431 2
The parties engaged in mediation of their dispute, with Board Judge Joseph A.
Vergilio serving as mediator.  Through the mediation, the parties have resolved their dispute. 
They have asked the Board to dismiss the appeal with prejudice to its reinstatement.
Accordingly, the appeal is DISMISSED WITH PREJUDICE.
_________________________
STEPHEN M. DANIELS
Board Judge
DISMISSED WITH PREJUDICE:  September 28, 2016
CBCA 4554, 4610
ALLTECH, INC.,
Appellant,
v.
DEPARTMENT OF HOMELAND SECURITY,
Respondent.
Jennifer A. Mahar and Stephen D. Knight of Smith Pachter McWhorter PLC,
Vienna, VA, counsel for Appellant.
Nathaniel J. Greeson, Heba K. Tellawi, Erik Claudio, and Samantha S. Ahrendt,
Office of Chief Counsel, Federal Emergency Management Agency, Department of
Homeland Security, Washington, DC, counsel for Respondent.
SOMERS, Board Judge.
ORDER
The Board is in receipt of the parties’ joint motion, filed on September 28, 2016, to
dismiss the above-referenced matters.  The parties request that the Board dismiss the
appeals with prejudice.
Accordingly, these appeals are DISMISSED WITH PREJUDICE. 
_________________________________
 JERI KAYLENE SOMERS
Board Judge
DISMISSED WITH PREJUDICE:  October 5, 2017
CBCA 5651, 5656
ALARES LLC,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Victor G. Klingelhofer of Cohen Mohr LLP, Washington, DC, counsel for Appellant.
Neil S. Deol, Office of General Counsel, Department of Veterans Affairs, Decatur,
GA, counsel for Respondent.
ZISCHKAU, Board Judge.
ORDER
On October 3, 2017, the appellant filed a joint request to dismiss the captioned appeals
based on a settlement reached by the parties.  The Board commends the parties on reaching
a settlement of their dispute.  Accordingly, the appeals are DISMISSED WITH
PREJUDICE.
________________________________
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED WITH PREJUDICE: December 20, 2011 
CBCA 2322 
FAB CONSTRUCTION, INC., 
Appellant, 
v.
 
DEPARTMENT OF VETERANS AFFAIRS,
 
Respondent. 
Robert Barry, FAB Construction, Inc., Mount Laurel, NJ, appearing for Appellant. 
Kate Gorney, Office of Regional General Counsel, Department of Veterans Affairs, 
Philadelphia, PA, counsel for Respondent. 
KULLBERG , Board Judge. 
ORDER 
On March 3, 2011, the Board docketed this appeal. Appellant and the Government 
subsequently settled this appeal in an alternative dispute resolution proceeding. 
By letter dated December 14, 2011, appellant requested that the Board dismiss this 
appeal with prejudice. 

 
      
______________________ 
  
 
2 CBCA 2322 
Accordingly, this appeal is DISMISSED WITH PREJUDICE . 
H. CHUCK KULLBERG 
Board Judge
GRANTED IN PART: July 11, 2016
CBCA 4770
FOULGER-PRATT CONTRACTING, LLC,
Appellant,
v.
DEPARTMENT OF STATE,
Respondent.
Joseph A. McManus, Jr., Daniel K. Felsen, David J. Butzer, and James P. Carney of
McManus & Felsen LLP, Washington, DC, counsel for Appellant.
Erin M. Kriynovich and John C. Sawyer, Office of the Legal Adviser, Buildings and
Acquisitions, Department of State, Washington, DC, counsel for Respondent.
Before Board Judges KULLBERG, WALTERS, and SULLIVAN.
KULLBERG, Board Judge.
On July 1, 2016, the parties submitted to the Board executed copies of a joint motion
for judgment on a stipulated settlement.  The parties requested that the Board enter judgment
in the amount of $6,500,000, with payment to be made through the judgment fund in
accordance with 31 U.S.C. § 1304 (2012) and 41 U.S.C. § 7108.  Rule 25(b) (48 CFR
6101.25(b) (2015)).  The parties have agreed that they will not seek appeal of,
reconsideration of, or relief from, the Board’s decision, and that each party will be
responsible for its costs, attorney fees, and expenses incurred in the litigation of this appeal.


CBCA 4770 2
Decision
The Board GRANTS IN PART the appeal.  The Department of State shall pay
appellant the sum of $6,500,000.  Payment shall be made from the judgment fund.  31 U.S.C.
§ 1304; 41 U.S.C. § 7108.
______________________
H. CHUCK KULLBERG
Board Judge
We concur:
_______________________ _______________________
RICHARD C. WALTERS MARIAN E. SULLIVAN
Board Judge Board Judge
DISMISSED WITH PREJUDICE:  April 26, 2010 
CBCA 1892 
XEROX CORPORATION, 
Appellant, 
v.
 
DEPARTMENT OF TRANSPORTATION,
 
Respondent. 
Donald J. Walsh of Offit Kurman, Owings Mills, MD, counsel for Appellant. 
Kimberly L. Moore, Office of the General Counsel, Department of Transportation, 
Washington, DC, counsel for Respondent. 
DANIELS , Board Judge (Chairman). 
ORDER 
Xerox Corporation (Xerox) contracted to sell and lease duplicating machines to the 
Department of Transportation, and to provide supplies and services to maintain those 
machines. Xerox alleges that it provided the machines, supplies, and services, but that the 
agency did not pay the amount invoiced for them, $70,854.81.   Xerox claimed entitlement 
to that amount.  It later appealed from the agency’s contracting officer’s deemed denial of 
the claim. 

__________________________________ 
2 CBCA 1892 
Xerox has now filed a notice to dismiss the appeal with prejudice, stating that the 
parties have settled the matter by payment of the amounts stated in the invoices at issue. 
Accordingly, the appeal is DISMISSED WITH PREJUDICE . 
STEPHEN M. DANIELS 
Board Judge
DISMISSED: December 2, 2014
CBCA 3923
SAYLOR CONSTRUCTION, INC.,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Jeffrey M. Gallant of Clark Hill PLC, Detroit, MI, counsel for Appellant.
Edith M. Bowman, Office of Regional Counsel, Department of Veterans Affairs,
Detroit, MI, counsel for Respondent.
DANIELS, Board Judge (Chairman).
ORDER
The Department of Veterans Affairs contracted with Saylor Construction, Inc. for
construction to upgrade the urgent care and emergency room at the agency’s health care
facility in Ann Arbor, Michigan.  The project was delayed due to agency actions, and the
agency compensated the contractor for some of the damages which were claimed to have
ensued.  The contractor appealed from the contracting officer’s decision which denied the
remainder of the claim.
Following a mediation session conducted by Board Judge Harold D. Lester, Jr., the
parties have entered into a settlement agreement and asked that the case be dismissed.  The
parties note in their joint motion that other claims may be made under this contract and that


CBCA 3923 2
any future claims are neither addressed in the settlement agreement nor affected by a
dismissal of the case.
As requested by the parties, this case is DISMISSED.
_________________________
STEPHEN M. DANIELS
Board Judge
____________________________ 
                         
                         
DISMISSED:  May 20, 2008 
CBCA 773 
EXPEDITORS, INC., dba TIGER WAREHOUSE, 
Appellant, 
v. 
DEPARTMENT OF AGRICULTURE, 
Respondent. 
Wayne Brockman, President of Expeditors, Inc., dba Tiger Warehouse, Kansas City, 
MO, appearing for Appellant. 
Christie J. Meller, Office of the General Counsel, Department of Agriculture, Kansas 
City, MO, counsel for Respondent. 
BORWICK, Board Judge. 
ORDER 
On May 19, 2008, appellant moved to dismiss the appeal.  Respondent does not 
object.  Pursuant to Rule 12(c), this appeal is DISMISSED . 
ANTHONY S. BORWICK 
Board Judge
DISMISSED WITH PREJUDICE:  April 7, 2025
CBCA 8194
STATE WAREHOUSE NOVA, LLC,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Gordon N. Griffin, Robert C. MacKichan, Jr., and Richard Ariel of Holland & Knight
LLP, Washington, DC, counsel for Appellant.
Elizabeth H. Johnson, Office of General Counsel, General Services Administration,
Washington, DC, counsel for Respondent.
VERGILIO, Board Judge.
ORDER
At the request of the parties, this appeal is DISMISSED WITH PREJUDICE,
pursuant to Board Rule 12(b)(2) (48 CFR 6101.12(b)(2) (2024)).
     Joseph   A. Vergilio         
JOSEPH A. VERGILIO
Board Judge
DISMISSED WITH PREJUDICE: June 10, 2014
CBCA 3622
TCG INTERNATIONAL, LLC,
Appellant,
v.
AGENCY FOR INTERNATIONAL DEVELOPMENT,
Respondent.
Joseph J. Petrillo of Petrillo & Powell, P.L.L.C., Washington, DC, counsel for
Appellant.
R. René Dupuy, Office of the General Counsel, Agency for International
Development, Washington, DC, counsel for Respondent.
DANIELS, Board Judge (Chairman).
ORDER
The Agency for International Development claimed that TCG International, LLC
(TCG), owed the agency $2,075,699 because it had not provided an incurred cost submission
for 2010, as required by a contract between the parties.  TCG appealed the contracting
officer’s decision which made this claim.
TCG has now provided the submission in question, and the contracting officer has
rescinded his decision, which resolves the matter in dispute.  The parties have jointly moved
the Board to dismiss the appeal with prejudice.

CBCA 3622 2
The motion is granted.  The appeal is DISMISSED WITH PREJUDICE.
_____________________________
STEPHEN M. DANIELS
Board Judge
DISMISSED WITH PREJUDICE:  January 15, 2026
CBCA 8130
KLAMATH WILDLIFE RESOURCES,
Appellant,
v.
DEPARTMENT OF AGRICULTURE,
Respondent.
Brian Shaw, Owner of Klamath Wildlife Resources, Redding, CA, appearing for
Appellant.
Adam J. Hermann, Office of the General Counsel, Department of Agriculture, Kansas
City, MO, counsel for Respondent.
ZISCHKAU, Board Judge.
ORDER
On January 15, 2026, appellant submitted, with respondent’s concurrence, a request
for dismissal of this appeal with prejudice in light of the contracting officer’s December 30,
2025, determination converting the original termination for cause into a termination for the
convenience of the agency.  Accordingly, the appeal is DISMISSED WITH PREJUDICE.
   Jonathan D. Zischkau    
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED WITH PREJUDICE:  May 14, 2018
CBCA 4523
CLEVELAND THERMAL, LLC,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Timothy Sullivan, Katherine S. Nucci, and Jayna Marie Rust of Thompson Coburn
LLP, Washington, DC, counsel for Appellant.
Justin S. Hawkins, Office of General Counsel, General Services Administration,
Washington, DC, counsel for Respondent.
ZISCHKAU, Board Judge.
ORDER
On May 2, 2018, the appellant, Cleveland Thermal, LLC, filed, with the concurrence
of the respondent, a motion to dismiss the captioned appeal.  The Board commends the
parties on the successful resolution of their dispute.  Accordingly, the appeal is
DISMISSED WITH PREJUDICE.
  Jonathan D. Zischkau    
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED WITH PREJUDICE:  February 28, 2023
CBCA 7437
SPECTRUM MANAGEMENT, LLC,
Appellant,
v.
DEPARTMENT OF LABOR,
Respondent.
Eden Brown Gaines of Brown Gaines, LLC, Washington, DC, counsel for Appellant.
José Otero and Christopher L. Sanders, Office of the Solicitor, Department of Labor,
Washington, DC, counsel for Respondent.
BEARDSLEY, Board Judge (Chair).
ORDER
On February 24, 2023, the parties filed a joint motion to dismiss this appeal with
prejudice after a settlement.  Accordingly, the appeal is DISMISSED WITH PREJUDICE. 
    Erica S. Beardsley          
ERICA S. BEARDSLEY
Board Judge
___________________________ 
DISMISSED WITH PREJUDICE:  March 5, 2007 
CBCA 377, 378, 379, 380, 381, 382, 383, 384, 574, 575 
BILL McGOWAN, INC.,
       Appellant, 
v. 
DEPARTMENT OF VETERANS AFFAIRS,
       Respondent. 
Bill McGowan, Jr., President of Bill McGowan, Inc., Covington, LA, appearin g 
for Appellant. 
Stacey  North Willis, Office of the General Counsel,  Depa rtment of Veterans 
Affairs, Washington, DC, counsel for Respondent. 
SHERIDAN , Board Judge. 
ORDER 
On February 28, 2 007, the parties provided the Board with an executed settlement 
agreement  indicating they had reached a resolution of the disputes associat ed with the 
above  captioned ap peals.  Pursuant to the agreement of the parties, and in accordance 
with  the settlement agreemen t entered into between the parties, the appeals of Bill 
McGowan,  Inc. , CBCA 377, 378, 379, 380, 381, 382, 383, 384, 574, and 575, are hereby 
DISMISSED WITH PREJUDICE . 
PATRICIA J. SHERIDAN 
Board Judge 

2 
#18662 CBCA377-384,574,575 BILLMcGOWAN,INC.doc 3/5/07 Reviewed by:PJS/
CLH
_______________________________ 
DISMISSED WITH PREJUDICE: March 8, 2011 
CBCA 2203 
MAGWOOD SERVICES, INC.,
                                                            Appellant. 
v. 
GENERAL SERVICES ADMINISTRATION,
                                                               Respondent. 
Heyward Manigault, President of Magwood Services, Inc., Campbell Hall, NY, 
appearing for Appellant. 
Scott F. McCleary, Office of Regional Counsel, General Services Administration, 
Chicago, IL, counsel for Respondent. 
WALTERS, Board Judge. 
ORDER 
The appeal has been settled, the parties advise that payment of the settlement amount 
has been made in full, and by joint motion, the parties have asked that the Board dismiss the 
appeal with prejudice. Accordingly, the appeal hereby is DISMISSED WITH 
PREJUDICE. 
RICHARD C. WALTERS 
Board Judge
DISMISSED WITH PREJUDICE: May 3, 2021
CBCA 7050
GO ENERGISTICS, LLC,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Sarah Schauerte Reida of Legal Meets Practical, LLC, Naperville, IL, counsel for
Appellant.
Peter S. Kozlowski, Jr., and Ellen McArthur, Office of General Counsel, Department
of Veterans Affairs, Eatontown, NJ, counsel for Respondent.
RUSSELL, Board Judge.
ORDER
The parties have jointly requested dismissal of this appeal with prejudice.  Pursuant
to Rule 12(b)(2) (48 CFR 6101.12(b)(2) (2019)), the request is granted.  This appeal is
hereby DISMISSED WITH PREJUDICE.
   Beverly M. Russell           
BEVERLY M. RUSSELL
Board Judge
DISMISSED WITH PREJUDICE: August 11, 2011 
CBCA 2162 
RLD COMPANY, INC., 
Appellant, 
v. 
DEPARTMENT OF AGRICULTURE, 
Respondent. 
Paul D. Donahue, President/CEO of RLD Company, Inc., Vancouver, WA, appearing 
for Appellant. 
Heather R. Hinton-Taylor, Office of the General Counsel, Department of Agriculture, 
Ogden, UT, counsel for Respondent. 
POLLACK, Board Judge. 
ORDER 
By letter dated August 3, 2011, the Board was notified by appellant that the parties 
had settled the matters at issue in the above-captioned appeal and appellant was requesting 
that the case be dismissed with prejudice. This matter had been the subject of mediation, 
with the Board waiting to dismiss the case until it had received notification that a settlement 
had been signed by the parties. 

                                                                                                                             
                                                                                         
_________________________________ 
2 CBCA 2162
 
Accordingly, the appeal is DISMISSED WITH PREJUDICE .
 
HOWARD A. POLLACK 
Board Judge
DISMISSED WITH PREJUDICE: May 17, 2021
CBCA 7118
AMERESCO, INC.,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Ron R. Hutchinson of Doyle & Bachman LLP, Arlington, VA, counsel for Appellant.
Jay Bernstein, Office of General Counsel, General Services Administration,
Washington, DC, counsel for Respondent.
BEARDSLEY, Board Judge.
ORDER
On May 14, 2021, appellant filed a motion to dismiss this appeal with prejudice. 
Respondent concurs with the motion.
Appellant’s motion is granted.  This appeal is DISMISSED WITH PREJUDICE.
    Erica S. Beardsley         
ERICA S. BEARDSLEY
Board Judge
DISMISSED WITH PREJUDICE: July 2, 2014
CBCA 3763
MORGEN & OSWOOD CONSTRUCTION CO., INC.,
Appellant,
v.
DEPARTMENT OF TRANSPORTATION,
Respondent.
Christopher A. Wright and Anne Marie Tavella of Watt, Tieder, Hoffar & Fitzgerald,
L.L.P., Seattle, WA, counsel for Appellant.
Rayann L. Speakman, Office of Division Counsel, Federal Highway Administration,
Department of Transportation, Vancouver, WA, counsel for Respondent.
KULLBERG, Board Judge.
ORDER
On June 17, 2014, appellant advised the Board that it did not want to proceed further
in this appeal and moved for a dismissal with prejudice.  Accordingly, this appeal is
DISMISSED WITH PREJUDICE.
______________________
H. CHUCK KULLBERG
Board Judge
DISMISSED WITH PREJUDICE:  April 23, 2008
 
CBCA 1057
 
TRAINING & DEVELOPMENT CORPORATION,
 
A p p e l l a n t , 
v. 
DEPARTMENT OF LABOR, 
Respondent. 
Charles Tetro, President of Training & Development Corporation, Bucksport, ME, 
appearing for Appellant. 
Herman J. Narcho, Office of the Solicitor, Department of Labor, Washington, DC, 
counsel for Respondent. 
HYATT, Board Judge. 
ORDER 
This appeal is of a contracting officer’s decision assessing liquidated damages in 
connection with Training & Development Corporation’s performance of a contract  to 
operate the Loring Job Corps Center in Maine.  In a conference held on March 19, 2008, the 
Government explained that the contracting officer’s decision had been issued pematurely 
and that the agency would like the opportunity to withdraw that opinion and reconsider its 
position.  Appellant had no objection to this request. 

    
 
2 CBCA 1057 
The contracting officer has officially withdrawn the decision that was appealed and 
docketed as CBCA 1057.  Following this action, respondent requested that this appeal be 
dismissed with prejudice.  Appellant does not object to dismissal of the appeal. 
Accordingly, this appeal is DISMISSED WITH PREJUDICE. This dismissal does 
not operate as an adjudication of the underlying claim in this appeal.
DISMISSED: June 9, 2011 
CBCA 1884, 1901, 1902, 1903, 1904, 1905, 
1906, 1907, 1908, 1909, 1910, 1911, 1912, 
1913, 1914, 1915, 1916, 1917 
RON ANDERSON CONSTRUCTION, INC., 
Appellant, 
v. 
DEPARTMENT OF VETERANS AFFAIRS, 
Respondent. 
William G. Beck and Michele A. Munson of Woods, Fuller, Shultz & Smith, P.C., 
Sioux Falls, SD, counsel for Appellant. 
Lindsay C. Roop and C. Charles Caruso, Office of Regional Counsel, Department of 
Veterans Affairs, Minneapolis, MN, counsel for Respondent. 
SOMERS , Board Judge. 
ORDER 
The Department of Veterans Affairs (VA) entered into a contract with Ron Anderson 
Construction, Inc. to remodel the VA Rehabilitative Medicine wing in Hot Springs, South 
Dakota. 

      
      
    
               
         
      
____________________________ 
  
 
2 CBCA 1884, 1901, 1902, 1903, 1904, 1905, 
1906, 1907, 1908, 1909, 1910, 1911, 1912, 
1913, 1914, 1915, 1916, 1917 
On May 31, 2011, the parties filed a request to dismiss the appeals, stating that the 
parties have fully settled and resolved the disputes at issue. 
Accordingly, the appeals are hereby DISMISSED . 
JERI KAYLENE SOMERS 
Board Judge
DISMISSED WITH PREJUDICE: September 10, 2007 
CBCA 443 
RIVERTECH, LLC, 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
Brett D. Orlove and Evan D. Harms of Grossberg, Yochelson, Fox & Beyda, LLP, 
Washington, DC, counsel for Appellant. 
Richard O. Hughes, Office of General Counsel, General Services Administration, 
Washington, DC, counsel for Respondent. 
PARKER , Board Judge. 
ORDER 
On March 20, 2006, Rivertech, LLC appealed the final decision of a General Services 
Administration contracting officer denying appellant’s claim for payments for certain capital 
improvements and repair work under lease number GS-11B-10192 at the Riverside at 
College Park Metro in Riverdale, Maryland. On September 7, 2007, appellant filed a motion 
to dismiss with prejudice, stating that the parties have reached a settlement in this appeal. 
Counsel for respondent has no objection. 

___________________________ 
2 CBCA 443
 
Accordingly, this appeal is DISMISSED WITH PREJUDICE .
 
ROBERT W. PARKER 
Board Judge
___________________________ 
  
 
DISMISSED WITH PREJUDICE: November 3, 2010 
CBCA 2086 
MICHAEL E. MURDOCK, 
Appellant, 
v.
 
GENERAL SERVICES ADMINISTRATION,
 
Respondent. 
Michael E. Murdock, pro se, Cincinnati, OH. 
Gabriel N. Steinberg, Office of Regional Counsel, General Services Administration, 
Atlanta, GA, counsel for Respondent. 
SOMERS , Board Judge. 
ORDER 
On July 13, 2010, appellant, Michael E. Murdock, appealed the final decision of a 
General Services Administration contracting officer imposing liquidated damages under 
contract number GS04F10FBE8593, sale number 41QSCH0368, lot 10. On November 2, 
2010, the parties filed a joint stipulation of dismissal, stating that they have reached a 
settlement and requesting that the appeal be dismissed with prejudice. 
Accordingly, the appeal is DISMISSED WITH PREJUDICE . 
JERI KAYLENE SOMERS 
Board Judge
DISMISSED WITH PREJUDICE:  May 21, 2024
CBCA 7934
RLS CONSTRUCTION GROUP,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Michael D. Rossiter, General Counsel of RLS Construction Group, Mechanicsburg,
PA, counsel for Appellant.
Jennifer L. Hedge, Office of General Counsel, Department of Veterans Affairs,
Pittsburgh, PA; and Timothy M. Saffles, Office of General Counsel, Department of Veterans
Affairs, Redwood City, CA, counsel for Respondent.
O’ROURKE, Board Judge.
ORDER
On May 20, 2024, the parties filed a joint motion to dismiss this appeal.  The motion
states that a settlement agreement has been executed by the parties resolving all claims under
this appeal.  The motion is granted.  This appeal is DISMISSED WITH PREJUDICE.
   Kathleen J. O’Rourke    
KATHLEEN J. O’ROURKE
Board Judge
____________________________________ 
   
 
 
DISMISSED WITH PREJUDICE: August 4, 2011 
CBCS 1413, 1414, 1415, 1416, 1417, 1418, 
1664, 1665, 1666, 1667, 1668 
CAUDELL-WHITE PROPERTIES, LLP, 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
Anthony O. L. Powell of Webb, Tanner, Powell, Mertz & Wilson, LLP, 
Lawrenceville, GA, counsel for Appellant. 
Lesley M. Busch, Office of General Counsel, General Services Administration, 
Washington, DC, counsel for Respondent. 
STERN , Board Judge. 
ORDER 
Subsequent to the filing of these appeals, appellant entered into bankruptcy 
proceedings. All matters were resolved and appellant moves to dismiss the appeals with 
prejudice. 
Accordingly, the appeals are hereby DISMISSED WITH PREJUDICE . 
JAMES L. STERN 
Board Judge
DISMISSED WITH PREJUDICE:  September 27, 2023
CBCA 7515
ACADEMI TRAINING CENTER, LLC,
Appellant,
v.
DEPARTMENT OF STATE,
Respondent.
Daniel J. Strouse of Cordatis LLP, Arlington, VA, counsel for Appellant.
Randal W. Wax, Office of the Legal Adviser, Buildings and Acquisitions, Department
of State, Washington, DC, counsel for Respondent.
ZISCHKAU, Board Judge.
ORDER
On September 27, 2023, the appellant filed a consent motion for voluntary dismissal
based on a final settlement of the parties’ dispute.  The Board commends the parties on their
successful resolution of the appeal.  Accordingly, the appeal is DISMISSED WITH
PREJUDICE.
  Jonathan D. Zischkau    
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED: December 31, 2012
CBCA 2903
JOINT VENTURE BETWEEN
G4S SECURE SOLUTIONS (PUERTO RICO), LTD., 
G4S SECURE SOLUTIONS INTERNATIONAL, INC. and 
G4S BARBADOS/GRENADA,
Appellant,
v.
DEPARTMENT OF STATE,
Respondent.
Eduardo F. Rodriguez of Avila Rodriguez Hernandez Mena & Ferri LLP, Coral
Gables, FL, counsel for Appellant.
Dennis J. Gallagher, Department of State, Rosslyn, VA, counsel for Respondent.
           
SHERIDAN, Board Judge.
ORDER
On December 13, 2012, representing that the parties had amicably resolved the
matters in controversy through a negotiated settlement, the appellant requested that the Board
enter an order dismissing this appeal.  Accordingly, CBCA 2903 is DISMISSED.
______________________
PATRICIA J. SHERIDAN
Board Judge
DISMISSED WITH PREJUDICE:  June 26, 2026
CBCA 8012, 8373
DELTA T JR, LLC,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
John Marshall Cook, Paul Marshall Ticer, and Evan Williams of Fox Rothchild, LLP,
Washington, DC, counsel for Appellant.
Marcia A. McCree, Office of General Counsel, Department of Veterans Affairs,
Washington, DC, counsel for Respondent.
VERGILIO, Board Judge.
ORDER
The parties have settled these disputes.  In accordance with their request, the appeals
are DISMISSED WITH PREJUDICE.  Board Rule 12(b)(2) (48 CFR 6101.12(b)(2)
(published in eCFR)).
     Joseph  A. Vergilio          
JOSEPH A. VERGILIO
Board Judge
DISMISSED WITH PREJUDICE:  October 25, 2016
CBCA 3348, 4638
TRADE CENTER MANAGEMENT ASSOCIATES, LLC,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Christopher J.  Brasco and Eric M. Liberman of Watt, Tieder, Hoffar & Fitzgerald,
LLP, McLean, VA, counsel for Appellant.
Justin S. Hawkins, Office of General Counsel, General Services Administration,
Washington, DC, counsel for Respondent.
ZISCHKAU, Board Judge.
On October 6 and 18, 2016, the respondent filed joint stipulations of dismissal in
CBCA 3348 and CBCA 4638, based on a settlement reached by the parties through
mediation of their dispute with Board Judge Stephen M. Daniels serving as mediator.  The
Board commends the parties on reaching a settlement of their dispute.  Accordingly, these
appeals are DISMISSED WITH PREJUDICE.
________________________________
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED WITH PREJUDICE: June 9, 2020
CBCA 6722
SOYINI A. RICHARDS,
Appellant,
v.
DEPARTMENT OF THE TREASURY,
Respondent.
Soyini A. Richards, pro se, Alexandria, VA.
Mary Schaffer, Office of the Chief Counsel, Bureau of the Fiscal Service, Department
of the Treasury, Parkersburg, WV, counsel for Respondent.
BEARDSLEY, Board Judge.
ORDER
On June 9, 2020, respondent filed a consent motion to dismiss this appeal with
prejudice. The parties have satisfied the conditions of the settlement agreement and resolved
all matters in the appeal. Appellant authorized the filing of the consent motion.
Accordingly, the motion is granted. The appeal is DISMISSED WITH
PREJUDICE.
Erica S. Beardsley
ERICA S. BEARDSLEY
Board Judge
DISMISSED WITH PREJUDICE:  June 23, 2026
CBCA 7771, 7830
COMP ENVIRONMENTAL, INC.,
Appellant,
v.
DEPARTMENT OF THE INTERIOR,
Respondent.
Caroline Wang, President of Comp Environmental, Inc., Winter Haven, FL, appearing
for Appellant.
Brian A. Quint, Office of the Solicitor, Department of the Interior, Washington, DC;
and Gregory Fetterman, Office of the Solicitor, Department of the Interior, Knoxville, TN,
counsel for Respondent.
ZISCHKAU, Board Judge.
ORDER
On June 18, 2026, the parties submitted a joint request for dismissal of these appeals
with prejudice in light of their resolution of the disputes.  The Board commends the parties
on the successful resolution of these matters.  Accordingly, these appeals are DISMISSED
WITH PREJUDICE.
   Jonathan D. Zischkau    
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED WITH PREJUDICE: April 22, 2014
CBCA 2722
WEST BAY BUILDERS, INC.,
Appellant,
v.
DEPARTMENT OF THE INTERIOR,
Respondent.
Timothy L. McInerney and Brian M. Junginger of McInerney & Dillon, P.C.,
Oakland, CA, counsel for Appellant.
Stephen R. Palmer, Office of the Regional Solicitor, Department of the Interior,
Sacramento, CA, counsel for Respondent.
SOMERS, Board Judge.
ORDER
On January 26, 2012, West Bay Builders, Inc. appealed the final decision of a
Department of the Interior, Bureau of Reclamation, contracting officer denying appellant’s 
claim for equitable adjustment under contract number R10PC20R09, entitled Red Bluff
Pumping Plant and Fish Screen, Landfill Excavation and Canal, Siphon and Access Bridge,
Central Valley Project, California.
On April 21, 2014, appellant requested that this appeal be dismissed with prejudice.


CBCA 2722 2
Accordingly, this appeal is DISMISSED WITH PREJUDICE.
___________________________
JERI KAYLENE SOMERS
Board Judge
DISMISSED WITH PREJUDICE: March 1, 2016
CBCA 2224
ABSHER CONSTRUCTION COMPANY,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Dennis P. Greenlee, Jr., General Counsel of Absher Construction Company, Puyallup,
WA, counsel for Appellant.
Richard O. Hughes, Office of Regional Counsel, General Services Administration,
New York, NY, counsel for Respondent.
DANIELS, Board Judge (Chairman).
ORDER
Absher Construction Company (Absher) constructed the United States Courthouse in
Seattle, Washington, under contract with the General Services Administration (GSA). 
Several years after the building was completed, problems arose with regard to the fire alarm
system.  GSA claimed that the problems were the result of latent defects in the system and
demanded that Absher pay repair costs in the amount of $272,500.  Absher appealed the
contracting officer’s decision, contending that any problems were the result of the agency’s
failure to maintain the system properly.


CBCA 2224 2
The contracting officer’s decision was issued in August 2010, and the appeal was filed
in November of that year.  By April 2011, the parties reported that they had reached a
tentative settlement of the case.  In February 2013, they represented that they had reached a
settlement and would “immediately finalize the appropriate settlement documents and jointly
move to dismiss the matter.”  On February 29, 2016, the parties finally filed a joint motion
to dismiss the case with prejudice.
The motion is granted.  The appeal is DISMISSED WITH PREJUDICE.
_________________________
STEPHEN M. DANIELS
Board Judge
DISMISSED WITH PREJUDICE: September 8, 2022
CBCA 7037
LINCOLN CONSTRUCTION GROUP, LLC,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
William E. O’Gara of Pannone Lopes Devereaux & O’Gara LLC, Johnston, RI,
counsel for Appellant.
Jennifer L. Hedge, Office of General Counsel, Department of Veterans Affairs,
Pittsburgh, PA; and Kathleen Ellis, Office of General Counsel, Department of Veterans
Affairs, Batavia, NY, counsel for Respondent.
BEARDSLEY, Board Judge.
ORDER
By motion filed on September 7, 2022, the parties jointly requested dismissal of this
appeal with prejudice, stating that they have executed a settlement agreement and all of the
claims have been resolved.  The motion is granted, and the appeal is DISMISSED WITH
PREJUDICE.
    Erica S. Beardsley    
ERICA S. BEARDSLEY
Board Judge
DISMISSED WITH PREJUDICE:  May 18, 2009 
CBCA 811 
RONALD D. MELTON, 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
Ronald D. Melton, pro se, Pensacola, FL. 
Gabriel N. Steinberg, Office of Regional Counsel, General Services Administration, 
Atlanta, GA, counsel for Respondent. 
HYATT , Board Judge. 
ORDER 
The parties have settled the dispute giving rise to this appeal, and the Government has 
been paid in full, as acknowledged by counsel for respondent in a letter dated May 12, 2009. 
The parties have jointly requested that the appeal be dismissed with prejudice pursuant to 
Board Rule 12. 

________________________________ 
2 CBCA 811 
Accordingly, this appeal is DISMISSED WITH PREJUDICE . 
CATHERINE B. HYATT 
Board Judge
DISMISSED WITH PREJUDICE:  May 17, 2019
CBCA 6092
JOSEFINA PERSINGER,
Appellant,
v.
DEPARTMENT OF AGRICULTURE,
Respondent.
Samantha P. Travis of Ogle, Worm & Travis, PLLP, Kalispell, MT, counsel for
Appellant.
Jennifer T. Newbold, Office of the General Counsel, Department of Agriculture,
Missoula, MT, counsel for Respondent.
LESTER, Board Judge.
ORDER
On May 14, 2019, the parties filed a joint motion to dismiss this appeal after having
entered into a settlement agreement resolving all matters in the appeal.  The parties’ motion
is granted.  This appeal is DISMISSED WITH PREJUDICE, with each party to bear its
own costs, attorney fees, and expenses.
    Harold D. Lester, Jr.      
HAROLD D. LESTER, JR.


CBCA 6092 2
Board Judge
____________________________ 
DISMISSED WITHOUT PREJUDICE: February 9, 2007 
CBCA 150 
THE RYAN COMPANY, 
Appellant, 
v. 
DEPARTMENT OF INTERIOR, 
Respondent. 
Leo McNamara of McNamara & Flynn, Boston, MA, counsel for Appellant. 
Elaine  England, Office of the Solicitor, Department of the Interior, Salt Lake City, 
UT, counsel for Respondent. 
DRUMMOND, Board Judge 
ORDER 
On February 2, 2007, appellant advised the Board that the  parties  have settled this 
matter  and moved to withdraw this appeal without  prejudice.  Without  objection, the stay of 
proceedings  or dered on  January 31, 2007, is lifted and this appeal is DISMISSED 
WITHOUT  PREJUDICE . This dismissal becomes with preju dice on August 10, 2007, 
unless a request is received at the Board before the date to delay such a conversion. 
JEROME M. DRUMMOND 
Board Judge
__________________________________ 
DISMISSED WITH PREJUDICE:  August 17, 2009 
CBCA 408 
ONBOARD SOFTWARE, INC., 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
Michael A. Gordon, Washington, DC, counsel for Appellant. 
Michael J. Noble, Office of General Counsel, General Services Administration, 
Washington, DC, counsel for Respondent. 
GOODMAN , Board Judge. 
ORDER 
On June 6, 2005, Onboard Software, Inc. filed a notice of appeal in connection with 
a dispute under contract number GS-35F-0117J, for the purchase of information technology 
professional services.  On August 13, 2009, the parties filed a joint motion to dismiss with 
prejudice, advising the Board that they have settled the appeal. 
Accordingly, this appeal is DISMISSED WITH PREJUDICE . 
ALLAN H. GOODMAN 
Board Judge
DISMISSED WITH PREJUDICE:  February 13, 2025
CBCA 8069
TALON VETERAN SERVICES, INC.,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Timothy J. Turner and Joshua Sather of Whitcomb, Selinsky, P.C., Denver, CO,
counsel for Appellant.
Jennifer L. Hedge, Office of General Counsel, Department of Veterans Affairs,
Pittsburgh, PA, counsel for Respondent.
O’ROURKE, Board Judge.
ORDER
On February 11, 2025, appellant, Talon Veteran Services, Inc., submitted a motion
to dismiss this appeal with prejudice.  The motion is granted.  Accordingly, the appeal is
DISMISSED WITH PREJUDICE.
   Kathleen J. O’Rourke    
KATHLEEN J. O’ROURKE
Board Judge
DISMISSED WITH PREJUDICE:  September 21, 2022
CBCA 7045
MASTER DESIGN BUILD, LLC,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
John M. Manfredonia of Manfredonia Law Offices, LLC, Cresskill, NJ, counsel for
Appellant.
Harold W. Askins, III, Office of General Counsel, Department of Veterans Affairs,
Charleston, SC; and Donald Mobly, Office of General Counsel, Department of Veterans
Affairs, Denver, CO, counsel for Respondent.
ZISCHKAU, Board Judge.
ORDER
On September 19, 2022, appellant filed a request for a voluntary dismissal of the
appeal.  The  respondent has no objection.  Accordingly, the appeal is DISMISSED WITH
PREJUDICE.
  Jonathan D. Zischkau    
JONATHAN D. ZISCHKAU
Board Judge
DISMISSED:  May 15, 2013  
 
 
 CBCA 3219 
  
 
 SCARANO BOAT BUILDERS, INC., 
 
Appellant, 
 
 v. 
 
 DEPARTMENT OF THE INTERIOR, 
 
Respondent. 
 
Ryan T. Donovan of Harris, Conway & Donovan PLLC, Albany, NY; and Lawrence H. 
Schaefer of Sheehan Greene Golderman & Jacques LLP, Albany, NY, appearing for 
Appellant. 
 
James E. Epstein, Office of the Northeast Regional Solicitor, Department of the Interior, 
Newton, MA, counsel for Respondent. 
 
BORWICK, Board Judge. 
 
 ORDER 
 
On May 14, 2013, the parties reported that they had reached a settlement of this 
matter and moved to dismiss the appeal.  Pursuant to the agreement of the parties and 
Rule 12(c), this appeal is DISMISSED. 
 
 
 
_________________________________ 
ANTHONY S. BORWICK 
Board Judge
DISMISSED WITHOUT PREJUDICE: November 7, 2011 
CBCA 2602 
TELOS CORPORATION, 
Appellant, 
v. 
DEPARTMENT OF VETERANS AFFAIRS, 
Respondent. 
Timothy Sullivan, Katherine S. Nucci and Scott F. Lane of Thompson Coburn, LLP, 
Washington, DC, counsel for Appellant. 
Ronald D. Sullivan, Office of General Counsel, Department of Veterans Affairs, 
Washington, DC, counsel for Respondent. 
DRUMMOND , Board Judge. 
ORDER 
Appellant has requested that it be permitted to withdraw the subject appeal without 
prejudice to its right to re-file an appeal within the requisite ninety-day period from the 
contracting officer’s final decision. On November 4, 2011, the Government advised the 
Board that it does not oppose this request. Accordingly, appellant’s request is granted. 

 
     
                                                                
  
 
2 CBCA 2602
 
This appeal is DISMISSED WITHOUT PREJUDICE .
 
JEROME M. DRUMMOND 
Board Judge
GRANTED IN PART: March 10, 2016
CBCA 3286, 3517, 3573, 3574, 3575
MASCARO CONSTRUCTION COMPANY, L.P.,
Appellant,
v.
GENERAL SERVICES ADMINISTRATION,
Respondent.
Michael D. Klein and Ross A. Giorgianni of Blumling & Gusky, LLP, Pittsburgh, PA;
Edward J. Sheats of Sheats & Bailey, PLLC, Brewerton, NY; Gregory P. Photiadis and Ryan
L. Belka of Duke, Holzman, Photiadis & Gresens, LLP, Buffalo, NY; and Christopher M.
Mills of Wiley Rein LLP, Washington, DC, counsel for Appellant.
Lori R. Shapiro and Justin Hawkins, Office of General Counsel, General Services
Administration, Washington, DC, counsel for Respondent.
Before Board Judges SHERIDAN, ZISCHKAU, and SULLIVAN.
SHERIDAN, Board Judge.
In these appeals, appellant, Mascaro Construction Company, L.P., appealed decisions
of a contracting officer of respondent, General Services Administration (GSA), arising from
its contract for construction of the Federal courthouse in Buffalo, New York. 
On February 8, 2016, the parties filed a joint motion for stipulated award for the Board
to enter a full and final judgment, stating in part that: 


CBCA 3517, 3573, 3574, 3575 2
7.  The parties desired to settle the Claims, Appeals, and any [sic] fully and
finally resolve any claims that Mascaro and/or its Subcontractors had or may
have had, so the parties entered into the Settlement Agreement.
8.  Under the Settlement Agreement, Mascaro shall accept on behalf of itself
and its subcontractors, the total sum of $11,000,000.00 (“Settlement
Amount”) in full and final settlement of all matters relating to the Contract,
including without limitation the Claims and Appeals.  To effect payment of the
Settlement Amount, the parties agreed to enter into a joint stipulation in which
the parties request that the Board enter final judgment in the total sum of
$11,000,000.00.  The Settlement Amount is inclusive of any costs, interest,
and attorney fees claimed or unclaimed, by Mascaro on behalf of itself and its
Subcontractors.
9.  Payment of the final judgment amount, that is $11,000,000.00, is to be
made from the permanent indefinite judgment fund.  31 U.S.C. § 1304 (2008).
10.  Pursuant to Rule 25(b) of the Board’s Rules of Procedure, the parties state
that neither party will seek reconsideration of, or relief from, the Board’s
decision, and they will not appeal the decision.
Decision
Accordingly, these appeals are GRANTED IN PART.  In accordance with the
parties’ motion, the Board awards the total sum of $11,000,000 to be paid from the judgment
fund.  This amount is inclusive of all costs, interest, and attorney fees. 
                                                             
PATRICIA J. SHERIDAN
Board Judge
We concur:
                                                                                                                          
JONATHAN D. ZISCHKAU MARIAN E. SULLIVAN
Board Judge Board Judge