MOTION TO DISMISS DENIED:  December 21, 2015
CBCA 2872
AURORA, LLC,
Appellant,
v.
DEPARTMENT OF STATE,
Respondent.
Richard C. Johnson, Richard H. Snyder, and Edmund M. Amorosi of Smith Pachter
McWhorter PLC, Vienna, VA; and  Peter F. Garvin, III, Grant H. Willis, and Ryan P.
McGovern of Jones Day, Washington, DC, counsel for Appellant.
John C. Sawyer, Thomas D. Dinackus, and Erin M. Kriynovich, Office of the Legal
Adviser, Buildings and Acquisitions, Department of State, Rosslyn, VA, counsel for
Respondent.
Before Board Judges SOMERS, HYATT, and LESTER.
HYATT, Board Judge.      
Respondent, the Department of State, has filed a motion to dismiss for lack of
jurisdiction this appeal of a contracting officer’s decision to terminate for default a design-
build contract it awarded to appellant, Aurora, LLC, for the construction of a consulate
compound in Jeddah, Saudi Arabia.  For the reasons stated, we deny the motion.

CBCA 2872 2
Background
Aurora and the State Department entered into contract number SAQMMA-07-C-0061,
for the design and construction of a new consulate in Jeddah, Saudi Arabia, on July 18, 2007. 
Initially, Aurora contemplated bidding on the contract under a joint venture arrangement with
First Kuwaiti Trading & Contracting, Inc. (First Kuwaiti).  To comply with security clearance
requirements, however, Aurora ultimately submitted a proposal under which it would be the
prime contractor, with First Kuwaiti as its principal subcontractor.1  In its capacity as
subcontractor, First Kuwaiti was responsible for the majority of the contract’s scope of work,
including responding to various task orders and issuing letters of credit that were necessary
to satisfy the contract’s payment and performance bond obligations. 
Aurora and First Kuwaiti began performance on the Jeddah contract on January 3,
2008.  In a letter dated November 3, 2009, State expressed concern with Aurora’s
performance of the project and questioned its ability to complete construction within the
twenty-eight month period scheduled under the contract.  On February 17, 2010, State issued
a cure notice to Aurora in which it raised the possibility that it would terminate the contract
for default.  Two months later, on April 15, 2010, the State Department followed up with a
show cause letter, repeating previously identified performance concerns and signaling an
intention to proceed with a termination for default.  On May 5, 2010, the contracting officer
officially notified Aurora that the Government was terminating the  contract for default and
intended to re-procure the remaining work.  Negotiations between the parties ensued, and on
October 5, 2010, Aurora and the State Department reached an agreement under which
performance on the contract was suspended while the State Department monitored Aurora’s
progress on a separate contract for the construction of a consulate compound in Surabaya,
Indonesia.  Under the agreement, the contract for construction of the Jeddah consulate would
be reinstated when the project in Surabaya was substantially complete.  The agreement
1 In early 2006, Aurora, through its predecessor company, Grunley-Walsh, LLC,
submitted a pre-qualification package to the State Department for upcoming United States
embassy construction opportunities.  That package proposed that a joint venture consisting
of Aurora and First Kuwaiti would complete the project, with Aurora responsible for
classified work and First Kuwaiti performing non-classified work.  Because First Kuwaiti
is a foreign entity, however, it was ineligible to hold the requisite security clearances needed
for the two entities to compete for the contract as a joint venture.  To work around this
obstacle, on December 27, 2006, Aurora and First Kuwaiti executed a subcontract agreement
under which Aurora would issue separate task orders for the performance of services and/or
delivery of products necessary for the completion of several pending and upcoming projects. 

CBCA 2872 3
established May 31, 2011, as the date by which the consulate in Surabaya was to be
substantially complete.
Substantial completion of performance under the Surabaya contract was not achieved
by May 31, 2011.  On October 31, 2011, the contracting officer notified Aurora that it
intended to terminate the Jeddah contract for default and to call in the line of credit furnished
by First Kuwaiti for the Jeddah contract.  On November 1, 2011, the contracting officer
issued a decision terminating the contract for default.  The contracting officer’s decision
referred to the terms of the October 2010 agreement, and the fact that substantial completion
of the Surabaya consulate contract had not occurred by May 31, 2011, to justify the
termination action.  Negotiations between the parties continued, however, and on January 26,
2012, the contracting officer agreed to rescind his decision and reconsider the termination
for default action.  After reviewing further arguments presented by Aurora and First Kuwaiti,
on March 30, 2012, the contracting officer issued a final decision terminating the contract
for default.  Upon termination of the Jeddah contract, the Government presented a demand
in full on the $10.7 million performance line of credit provided by First Kuwaiti.
On June 26, 2012, the Board received a notice of appeal, captioned as “Aurora, LLC,”
and stating that “Aurora hereby appeals the State Department’s March 30, 2012 notice of
termination for default.”  The notice of appeal was signed by “[c]ounsel for First Kuwaiti
Trading & Contracting, W.L.L., appealing in the name of Aurora, LLC.”  A notice of
appearance was entered by counsel for First Kuwaiti, “appealing in the name of Aurora,
LLC.”  Aurora did not have separate counsel enter a notice of  appearance on its own behalf
until January 20, 2015.
A complaint was filed in the appeal on December 14, 2012, seeking the following
relief:
55. Aurora respectfully requests that the Board order [the State Department]
to withdraw the termination for default on the Jeddah Contract and issue a
termination for the Government’s convenience.
56. Aurora requests that the Board order [the State Department] to return
the $10.7 million [the State Department] withdrew from [First Kuwaiti’s]
performance LOC [line of credit] on the Jeddah Contract.  Aurora also
requests the award of any and all additional costs associated with the
Government’s termination for convenience.
During the conduct of discovery, the Government inquired of First Kuwaiti’s attorneys
regarding First Kuwaiti’s and Aurora’s interest in the appeal and First Kuwaiti’s authority

CBCA 2872 4
to litigate the appeal.  The initial authorization of the appeal is reflected in an email exchange
from June 26 to 27, 2012, between Aurora’s president and counsel for First Kuwaiti.  In that
exchange, Aurora confirmed that it had “no objection to First Kuwaiti appealing the default
termination of the Jeddah . . . Contract (SAQMMA-07-C-006) in the name of Aurora, with
the proceeds of such appeal to be paid to First Kuwaiti.”  Aurora further stated its expectation
that the details would be worked out in a separate agreement, and reserved the right to
rescind the authorization should an agreement not be obtained. 
A pass-through agreement executed by the parties and dated May 22, 2013, was
provided to the Government on January 14, 2014.  The agreement stated that “Prime and
Subcontractor have already agreed, as confirmed by email dated June 26, 2012, that Prime
would allow Subcontractor to appeal Owner’s default termination on Contract SAQMMA-
07-C-0061 in the name of Prime, with additional details to be set forth in a separate
agreement.”  
The State Department requested further information concerning the referenced
“separate agreement” in the pass-through agreement.  In response, First Kuwaiti’s counsel
forwarded a copy of the email exchange from June 26-27, 2012, and stated that “the
subsequently signed pass-through agreement is the ‘separate agreement.’  There is not
another agreement.” 
On December 31, 2014, counsel for the Government received an email message from
Aurora’s counsel forwarding a letter sent by Aurora to First Kuwaiti.  In that letter, Aurora
asserted that the pass-through agreement provided to the Government was invalid due to
problems with the terms of the agreement and issues with a separate, related agreement.  The
letter from Aurora to First Kuwaiti, dated December 23, 2014, stated grounds upon which
Aurora believed the pass-through agreement to be invalid and unenforceable.  On page five
of the letter, Aurora stated:
No valid sponsorship agreement exists and there is no prime contractor
authorization of [First Kuwaiti’s] appeal and claims to State other than the
June 27, 2012 provisional authorization related to the Jeddah appeal only. 
That provisional authorization fails to include the essential terms of a valid
sponsorship agreement and does not fully comport with the applicable CDA 
requirements. 
On January 14, 2015, Aurora provided the Government with a copy of the June 27,
2012, email message and stated that it had sponsored the appeal through that email message.
Aurora further explained that the email sponsorship was followed by a written pass-through
agreement which was later determined to be unenforceable.  Aurora confirmed that the email

CBCA 2872 5
message of June 27, 2012, was still valid and that the sponsorship was still in effect and
would remain in effect while the parties negotiated a detailed, written sponsorship agreement. 
Counsel for Aurora has also entered a separate appearance in the appeal and confirmed
Aurora’s continued authorization of the appeal.
Discussion
The Government’s motion to dismiss for lack of jurisdiction initially focused on the
internal dispute existing between Aurora and First Kuwaiti respecting the terms of the side
agreement and pass-through arrangements.  The State Department construed this dispute to
be tantamount to a repudiation of Aurora’s agreement to permit First Kuwaiti to challenge
the termination for default in its name.  This lack of agreement over the terms of a pass-
through arrangement, according to the State Department, divested First Kuwaiti of any
entitlement to pursue this action in Aurora’s name.  Under established precedent governing
the pass-through claims of subcontractors, in the absence of continued sponsorship, the State
Department reasoned, the appeal must be dismissed.  
The State Department’s motion made the further argument that even if the Board were
to find that Aurora has sponsored the appeal from the outset and continues to do so, the law
pertaining to sponsorship of claims only extends to sponsorship of a subcontractor’s own
claim for monetary damages and does not permit a prime contractor to assign the prime
contractor’s right to appeal to a subcontractor.  The Government asserted that the right to
challenge a termination for default decision is solely that of the prime contractor and cannot
be assigned to another party.  Since, according to the State Department, First Kuwaiti was
not directly harmed by the termination for default of Aurora’s contract, it cannot be a proper
party for sponsorship.  Additionally, the Government maintains, First Kuwaiti’s principal
interest in the appeal is the recovery of its line of credit, which it provided in its capacity as
a surety, not a subcontractor.  To demonstrate the correctness of its position, the State
Department points to the complaint, which seeks an award of the amount of $10,700,000
representing the proceeds of the letter of credit drawn upon by the Government after the
termination of Aurora’s contract.  
Following the submission of responses by both Aurora and First Kuwaiti to the
Government’s motion, and a conference convened by the Board, the Government further
refined its position in this regard, emphasizing its concerns about the improper “expansion”
of the sponsorship case law to allow a subcontractor to proceed in the absence of its own
claim, and recasting its objection to the arrangement as an improper attempt by Aurora to
“assign” its own “claim” to First Kuwaiti under the guise of sponsorship, thus violating the
prohibition against the assignment of claims.  

CBCA 2872 6
The Contract Disputes Act (CDA), 41 U.S.C. §§ 7101-7109 (2012), prescribes the
Board’s jurisdiction to decide disputes arising under federal government contracts.
Jurisdiction is a threshold matter, and where the Board lacks subject matter jurisdiction, it
may not proceed to decide the merits of the case.  ARI University Heights, LP v. General
Services Administration, CBCA 4660, 15-1 BCA ¶ 36,085, at 176,188; Safe Haven
Enterprises, LLC v. Department of State, CBCA 3871, et al., 15-1 BCA ¶ 35,928, at 175,603
(citing England v. Swanson Group, Inc., 353 F.3d 1375, 1379 (Fed. Cir. 2004)); McAllen
Hospitals LP v. Department of Veterans Affairs, CBCA 2774, et al., 14-1 BCA ¶ 35,758, at
174,969 (citing Steel Co. v. Citizens for a Better Environment, 523 U.S. 83, 94-95 (1998)). 
It is appellant’s burden to establish subject matter jurisdiction by a preponderance of the
evidence.  Safe Haven Enterprise, 15-1 BCA at 175,603 (citing Reynolds v. Army & Air
Force Exchange Service, 846 F.2d 746, 748 (Fed. Cir. 1988)).
The Monetary Claims Presented in the Complaint
Before addressing the State Department’s principal jurisdictional arguments
concerning the appeal of the termination action, we turn to Aurora’s request for monetary
relief in the complaint.  In its complaint, Aurora has requested an award of $10.7 million in
damages, representing the amount of money that State withdrew from First Kuwaiti’s line
of credit following the termination action, and “any and all additional costs associated with
the Government’s termination for convenience.”  The Board has recently addressed a similar
situation involving a termination for default action:
Before the Board can exercise jurisdiction over a contractor’s request for
monetary damages, the contractor must have submitted a written claim to the
contracting officer for a decision.  Shaw Environmental, Inc. v. Department of
Homeland Security, CBCA 2177, et al., 13 BCA ¶ 35,188, at 172,667 (2012)
(citing 41 U.S.C. §§ 7103(a), 7105(e)(1)(A)).  There are three basic
requirements for a valid CDA monetary claim: “(1) the contractor must submit
the demand in writing to the contracting officer, (2) the contractor must submit
the demand as a matter of right, and (3) the demand must include a sum
certain.”  H.L. Smith, Inc. v. Dalton, 49 F.3d 1563, 1565 (Fed. Cir. 1995). 
“The CDA also requires that a claim indicate to the contracting officer that the
contractor is requesting a final decision,” although this request need not be
explicit.  M. Maropakis Carpentry, Inc. v. United States, 609 F.3d 1323, 1327
(Fed. Cir. 2010).
1-A Construction & Fire, LLP v. Department of Agriculture, CBCA 2693, 15-1 BCA
¶ 35,913 at 175,563-64, appeal docketed, No. 2015-1623 (Fed. Cir. May 4, 2015).  Until

CBCA 2872 7
Aurora submits a written claim for monetary damages to the contracting officer for decision,
and appeals an unfavorable decision, we lack jurisdiction to entertain its monetary demand.2
The Subcontractor/Sponsorship Issues
The State Department contends that the appeal should be dismissed because First
Kuwaiti, as a subcontractor, is not the proper party to challenge the termination for default. 
The CDA expressly defines the term “contractor” to mean a party to a federal government
contract other than the Federal Government.  Id. at § 7101(7).  The Court of Appeals for the
Federal Circuit, noting that a waiver of sovereign immunity must be “strictly construed in
favor of the sovereign,” has held that “those who are not in privity of contract with the
government cannot avail themselves of the CDA’s appeal provisions.”  Winter v. FloorPro,
Inc., 570 F.3d 1367, 1370-71 (Fed. Cir. 2009).   The Board has further elaborated that: 
The requisite privity of contract needed to permit an appeal under the CDA has 
generally been limited to prime contractors who have actually contracted with
the Government.  Attempts by other parties, such as subcontractors and
sureties, to extend the concept of privity beyond the prime contractor have
typically been rejected. 
Eagle Peak Rock & Paving, Inc. v. Department of the Interior, CBCA 2770, 12-2 BCA
¶ 35,146, at 172,521 (citations omitted); accord Security Enforcement Authority, Inc. v.
Department of Homeland Security, CBCA 3238, 14-1 BCA ¶ 35,725; Magwood Services,
Inc. v. Department of Transportation, CBCA 3630, 14-1 BCA ¶ 35,605 at 174,413.  At the
same time, it is also well established that subcontractors may pursue claims against the
Government under the proper sponsorship of, and in the name of, the prime contractor.  E.g.,
2 As we pointed out in 1-A Construction, even if we were to view Aurora’s
monetary request as a request for termination for convenience settlement costs that it could
receive if the State Department’s default termination were overturned, the mere conversion
of the agency’s default termination to a convenience termination would not automatically
vest us with jurisdiction over Aurora’s request for such costs.  15-1 BCA at 175,566 n.12
(citing  Swanson Group, Inc., ASBCA 52109, 04-1 BCA ¶ 32,603, at 161,324-25).  Before
we could consider any request for termination settlement costs, the contractor would still
have to submit a termination settlement proposal to the agency, after which time the proposal
would have to ripen into a claim.  Id. (citing James M. Ellett Construction Co. v. United
States, 93 F.3d 1537, 1543-44 (Fed. Cir. 1996)).
 

CBCA 2872 8
Cooley Constructors, Inc. v. General Services Administration, CBCA 3905, 15-1 BCA ¶
36,001; TAS Group, Inc. v. Department of Justice, CBCA 52, 07-2 BCA ¶ 33,630. 
Because the parties have used the nomenclature common to sponsored claims, they
have framed their arguments to fit the case law in this area.  The case law developed to
address sponsorship arrangements in which a subcontractor wishes to pursue its own
monetary claim has no practical application to the circumstances presented in this appeal,
which at this time involves solely a challenge to the propriety of a default termination.  This
is because a default termination is a government claim.  Malone v. United States, 849 F.2d
1441, 1443 (Fed. Cir. 1988); Lisbon Contractors, Inc. v. United States, 828 F.2d 759, 764-65
(Fed. Cir. 1987); Paradise Pillow, Inc. v. General Services Administration, CBCA 3562, slip
op. at 7 (Oct. 27, 2015).  Absent a separate claim, or claims, for equitable adjustment of the
contract price or for convenience termination damages, the only relief available under an
appeal of a default termination is the conversion of the default termination to one for the
convenience of the Government.  As such, there is no subcontractor monetary claim to
sponsor.3  
The lack of an independent subcontractor claim does not divest the Board of
jurisdiction, however.  We note that Aurora has met its burden to show that the arrangement
with First Kuwaiti was properly authorized so as to establish that it did, indeed, timely appeal
the contracting officer’s decision.  The appeal was filed in the name of Aurora, with Aurora’s
3 This disposes of any argument, based on Severin v. United States, 99 Ct. Cl.
435 (1943), that Aurora is not liable to First Kuwaiti for damages, thus invalidating a
sponsored appeal.  We are mindful that monetary claims for both parties would likely follow
should the Government fail to justify the default termination decision and the appeal is
sustained.  In addition, although technically there is no subcontractor claim to sponsor at this
time, the overturning of the default termination is a necessary predicate to subsequent
monetary claims likely to be asserted by both companies.  Given the close collaboration of
Aurora and First Kuwaiti in performing the contract until termination, moreover, it seems
likely that the observations offered in Erickson Air Crane Co. of Washington v. United
States, 731 F.2d 810 (Fed. Cir. 1984), would  apply:
[P]rime contractors often do allow subcontractors to prosecute claims in the
prime’s name when they perceive that the subcontractors really have more at
stake in a claim and are therefore willing to work harder on its enforcement.
Subcontractors may also be the only ones in full possession of the facts. 
Id. at 813. 

CBCA 2872 9
authorization.  Aurora, as the prime contractor, clearly had, and has, standing to challenge
the Government’s decision to terminate the contract for default.  We know of no legal ground
to dismiss the matter simply because Aurora has, up until now, been willing to allow First
Kuwaiti to assume the laboring oar on its behalf.  It is still Aurora’s appeal, and the
Government is answerable only to Aurora.4
Similarly, the Government’s concerns about an improper “assignment” of Aurora’s
rights in this matter are misplaced.  The Assignment of Contracts Act, 41 U.S.C. § 6305
(2012), and the Assignment of Claims Act, 31 U.S.C. § 3727 (2012), are intended to prevent
fraud, particularly the buying up of claims against the Government; to protect the
Government from having to deal with multiple persons or strangers to the contract; and to
eliminate conflicting demands for payment and chances of multiple litigation and liability. 
See Merlin International, Inc. v. Department of Homeland Security, CBCA 2570, 11-2 BCA
¶ 34,869, at 171,510.  Aside from the fact that the claim here is that of the Government, none
of the concerns underlying the prohibitions against assignment of claims and contracts  exist
when the proper party to pursue the appeal – in this case, Aurora – is before the Board.  Id.
(citing Beaconwear Clothing Co. v. United States, 355 F.2d 583, 591 (Ct. Cl. 1966)).
 
To conclude, the only issue before the Board is the propriety of the default
termination.  Since the proper party to appeal the contracting officer’s decision has done so,
there is no basis to dismiss this appeal on jurisdictional grounds.
Decision
The motion to dismiss is DENIED.  Aurora’s request for monetary damages is
DISMISSED FOR LACK OF JURISDICTION.
__________________________________
CATHERINE B. HYATT
Board Judge
4 In this regard, we note that, as the Court commented in Erickson Crane, 
whatever their private arrangements, Aurora and First Kuwaiti are nonetheless treated as one
party for the purposes of this appeal.  They are expected to cooperate with each other such
that there is no added burden to the tribunal in adjudicating this matter.  731 F.2d at 814. 

CBCA 2872 10
We concur:
___________________________________ __________________________________
JERI KAYLENE SOMERS HAROLD D. LESTER, JR.
Board Judge Board Judge