GRANTED IN PART: July 23, 2015
CBCA 4778
BRASFIELD & GORRIE, LLC,
Appellant,
v.
DEPARTMENT OF VETERANS AFFAIRS,
Respondent.
Laurence Schor, Dennis C. Ehlers, and Robert D. Pratt of Asmar, Schor & McKenna,
PLLC, Washington, DC; and Axel Bolvig III, Luke D. Martin, and J. Christopher Selman of
Bradley Arant Boult & Cummings, LLP, Birmingham, AL, counsel for Appellant.
Stacey North-Willis, Beth Chesney, Benjamin Diliberto, and Charlma Quarles, Office
of the General Counsel, Department of Veterans Affairs, Washington, DC, counsel for
Respondent.
Before Board Judges DANIELS (Chairman), HYATT, and VERGILIO.
DANIELS, Board Judge.
The Department of Veterans Affairs (VA) and Brasfield & Gorrie, LLC (B&G)
entered into a contract for the construction of a hospital and clinic at the VA’s Medical
Center in Orlando, Florida.  The original contract was in the amount of $276,773,030.
In the course of construction, B&G submitted many claims to the VA.  Among them
was claim 6, for damages the contractor and its subcontractors allegedly incurred during the
period from January 1 to December 31, 2014, as a result of the VA’s allegedly “defective


CBCA 4778 2
design, failure to timely select medical equipment, maladministration of the Contract, illegal
directive to accelerate performance, improper withholding of earned contract funds, improper
assessment of liquidated damages, uncompensated changes and other causes.”  This claim
is for a 311-day extension of contract time, 146 days of compensable time, and associated
costs in the amount of $51,976,624.
The VA contracting officer decided that B&G was entitled to additional contract time
and may be entitled to additional compensation, but that the contractor “ha[d] not established
entitlement for specific time and compensation claimed.”  B&G appealed the decision, and
the Board docketed the appeal as CBCA 4778.
The parties have now filed a joint motion for stipulated judgment pursuant to Board
Rule 25(b) (48 CFR 6101.25(b) (2014)).  In this motion, they ask the Board to award to B&G
$46,289,105, plus interest calculated pursuant to the Contract Disputes Act, 41 U.S.C. § 7109
(2012), from April 10, 2015, until the date of payment; and an extension of the contract
completion date by 146 calendar days.
The parties state that B&G will not seek attorney fees in conjunction with the
prosecution of these appeals.  The parties state further that they will not seek reconsideration
of, or relief from, a Board decision which awards the stipulated amount and extension of
contract completion date, and that they will not appeal the decision.
Decision
CBCA 4778 is GRANTED IN PART.  The Department of Veterans Affairs shall pay
to Brasfield & Gorrie, LLC, $46,289,105, plus interest calculated pursuant to the Contract
Disputes Act from April 10, 2015, until the date of payment.  This payment may be made
from the permanent indefinite judgment fund, 31 U.S.C. § 1304.
The Board also extends the contract completion date, as stipulated by the parties in
their joint motion.
_________________________
STEPHEN M. DANIELS
Board Judge

CBCA 4778 3
We concur:
_________________________ _________________________
CATHERINE B. HYATT JOSEPH A. VERGILIO
Board Judge Board Judge