GRANTED IN PART: June 8, 2010 
CBCA 1460 
WALSH/DAVIS JOINT VENTURE, 
Appellant, 
v. 
GENERAL SERVICES ADMINISTRATION, 
Respondent. 
Barbara G. Werther of Howrey LLP, Washington, DC; and J. Richard Margulies of 
J. Richard Margulies & Associates, Ltd., Rockville, MD, counsel for Appellant. 
Dalton F. Phillips, Leigh Erin S. Izzo, and Heather R. Cameron, Office of General 
Counsel, General Services Administration, Washington, DC, counsel for Respondent. 
Before Board Judges DANIELS  (Chairman), STERN , and HYATT . 
DANIELS , Board Judge. 
The General Services Administration (GSA) contracted with Walsh/Davis Joint 
Venture (Walsh/Davis) for the construction of a building in Washington, D.C., to serve as 
the headquarters of the Department of Justice’s Bureau of Alcohol, Tobacco, Firearms and 
Explosives.  Walsh/Davis submitted to the GSA contracting officer numerous claims relating 
to this work.  The contracting officer denied the claims in a 123-page decision.  Walsh/Davis 
appealed. 
The parties have resolved various matters at issue in the case and have asked us to 
make stipulated awards to Walsh/Davis, on a subject matter by subject matter basis.  We 

 
    
 
   
 
       
 
 
  
 
_________________________ 
2 CBCA 1460 
issued decisions on motions for stipulated award as to most of the direct cost claims on 
June 3, 2009 (later amended, per the parties’ joint requests, on July 17, 2009, and 
September 8, 2009), and on claims numbered 179 through 197 and the “Ned Kahn 
Deduction” on December 15, 2009. 
By motion filed on June 7, 2010, the parties have asked us to make a stipulated award 
to Walsh/Davis as to certain delay and inefficiency claims involving Walsh/Davis and its 
subcontractors Archer Western, Inc.; Cleveland, Inc.; John J. Kirlin, Inc. and its 
subcontractor, Superior Air Handling Corporation; James Myers Company; and Global 
Precast, Inc.  In this motion, the parties ask that we enter judgment for Walsh/Davis in the 
amount of $1,434,544, plus, if that amount has not been paid by July 15, 2010, interest on 
the amount from July 15, 2010, until the amount and all accrued interest are paid.  The 
judgment amount includes costs, attorney fees, and interest up to and including July 15, 2010. 
The parties have stated that neither of them will seek reconsideration of or relief from a 
decision which directs payment from the permanent indefinite judgment fund in the specified 
amount, and neither of them will appeal such a decision. 
Decision 
This appeal is GRANTED IN PART .  As to the specified delay and inefficiency 
claims involving Walsh/Davis and its subcontractors Archer Western, Inc.; Cleveland, Inc.; 
John J. Kirlin, Inc. and its subcontractor, Superior Air Handling Corporation; James Myers 
Company; and Global Precast, Inc., GSA shall pay to Walsh/Davis $1,434,544.  If this 
amount is not paid by July 15, 2010, interest shall accrue on the unpaid portion from that date 
until the principal and all accrued interest are paid.  Interest shall be at the rates specified 
pursuant to 41 U.S.C. § 611 (2006).  Payment shall be made from the permanent indefinite 
judgment fund.  31 U.S.C. § 1304. 
STEPHEN M. DANIELS 
Board Judge 

_________________________ _________________________ 
3 CBCA 1460 
We concur: 
JAMES L. STERN CATHERINE B. HYATT 
Board Judge Board Judge